Loading...
Backup Documents 06/08/2021 Item #16C12 (Coastal Concrete Products, LLC) C1z ORIGINAL DOCUMENTS CHECKLIST & ROUTING SLIP TO ACCOMPANY ALL ORIGINAL DOCUMENTS SENT TO THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR SIGNATURE Print on pink paper. Attach to original document. The completed routing slip and original documents are to be forwarded to the County Attorney Office at the time the item is placed on the agenda. All completed routing slips and original documents must be received in the County Attorney Office no later than Monday preceding the Board meeting. **NEW** ROUTING SLIP Complete routing lines#1 through#2 as appropriate for additional signatures,dates,and/or information needed. If the document is already complete with the exception of the Chairman's signature,draw a line through routing lines#1 through#2,complete the checklist,and forward to the County Attorney Office. Route to Addressee(s) (List in routing order) Office Initiiallss Datef 124 1. Risk Risk Management 4! � 2. County Attorney Office County Attorney Office W OA/ 4. BCC Office Board of County ?TAf 5 � Commissioners 4. Minutes and Records Clerk of Court's OfficeINA) r,I 5. Procurement Services Procurement Services PRIMARY CONTACT INFORMATION Normally the primary contact is the person who created/prepared the Executive Summary. Primary contact information is needed in the event one of the addressees above,may need to contact staff for additional or missing information. Name of Primary Staff Jessica Suarez/PURCHASING Contact Information 239-252-8407 Contact/ Department Agenda Date Item was June 8th 2021 Agenda Item Number 16.C.12 Approved by the BCC Type of Document AGREEMENT Number of Original 1 Attached Documents Attached PO number or account N/A 20-7789 COASTAL number if document is COASTAL CONCRETE to be recorded CONCRETE PRODUCTS,LLC PRODUCTS,LLC DBA COASAL DBA COASAL SITE SITE DEVELOPMENT DEVELOPMENT INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable column,whichever is Yes N/A(Not appropriate. (Initial) Applicable) 1. Does the document require the chairman's original signature STAMP OK N/A 2. Does the document need to be sent to another agency for additional signatures? If yes, N/A provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be JS signed by the Chairman,with the exception of most letters,must be reviewed and signed by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the JS document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's JS signature and initials are required. 7. In most cases(some contracts are an exception),the original document and this routing slip N/A should be provided to the County Attorney Office at the time the item is input into SIRE. Some documents are time sensitive and require forwarding to Tallahassee within a certain time frame or the BCC's actions are nullified. Be aware of your deadlines! 8. The document was approved by the BCC on 06/08/2021 and all changes made during Rif b/ the meeting have been incorporated in the attached document. The County U• va gptigp,for Attorney's Office has reviewed the changes,if applicable. . t s t 9. Initials of attorney verifying that the attached document is the version approved by the N/A is not BCC,all changes directed by the BCC have been made,and the document is ready for the s�: aptioncfnt Chairman's signature. this line. 16C12 MEMORANDUM Date: June 15, 2021 To: Jessica Suarez, Purchasing Technician Procurement Services From: Martha Vergara, Sr. Deputy Clerk Minutes & Records Department Re: Contract #20-7789 "Multi-Contractor Award Agreement" for Designated Driveway Contractor Services Contractor: Coastal Concrete Products, LLC d/b/a Coastal Site Development, Inc. Attached for your records is an original of the referenced document above, (Item #16C12) adopted by the Board of County Commissioners on Tuesday, June 8, 2021. The Board's Minutes & Records Department has kept an original as part of the Board's Official Records. If you have any questions, please feel free to contact me at 252-7240. Thank you. Attachment 1 C1 ,2 MULTI-CONTRACTOR AWARD AGREEMENT # 20-7789 for DESIGNATED DRIVEWAY CONTRACTOR SERVICES THIS AGREEMENT, made and entered into on this L. day of ckktflid 20 21 , by and between Coastal Concrete Products, LLC d/b/a Coastal Site Development authorized to do business in the State of Florida, whose business address is 7742 Alico Road, Fort Myers, FL 33912 , (the "Contractor") and Collier County, a political subdivision of the State of Florida, (the "County" or "Owner"): WITNESSETH: 1. AGREEMENT TERM. The Agreement shall be for a three ( 3 ) year period, commencing IJ upon the date of Board approval; or I I on , and terminating three ( 3 ) year(s) from that date or until all outstanding I* Purchase Order(s) X Work Order(s) issued prior to the expiration of the Agreement period have been completed or terminated. The County may, at its discretion and with the consent of the Contractor, renew the Agreement under all of the terms and conditions contained in this Agreement for two ( 2 ) additional one ( 1 ) year(s) periods. The County shall give the Contractor written notice of the County's intention to renew the Agreement term prior to the end of the Agreement term then in effect. The County Manager, or his designee, may, at his discretion, extend the Agreement under all of the terms and conditions contained in this Agreement for up to one hundred and eighty (180) days. The County Manager, or his designee, shall give the Contractor written notice of the County's intention to extend the Agreement term prior to the end of the Agreement term then in effect. 2. COMMENCEMENT OF SERVICES. The Contractor shall commence the work upon issuance of a IuIPurchase Order *Notice to Proceed. 3. STATEMENT OF WORK. The Contractor shall provide services in accordance with the terms and conditions of I I Request for Proposal (RFP) I I B I.I Other: Invitation for Qualification ( IFQ ) # 20-7789 including all Attachment(s), Exhibit(s) and Addenda and the Contractor's proposal referred to herein and made an integral part of this Agreement. I■I The Contractor shall also provide services in accordance with Exhibit A — Scope of Services attached hereto. 3.1 This Agreement contains the entire understanding between the parties and any modifications to this Agreement shall be mutually agreed upon in writing by the Parties, in compliance with the County's Procurement Ordinance, as amended, and Procurement Procedures in effect at the time such services are authorized. Page 1 of 33 Multi-Contractor Award Agreement[2021_ver.1] l6Cl2 3.2 The execution of this Agreement shall not be a commitment to the Contractor to order any minimum or maximum amount. The County shall order items/services as required but makes no guarantee as to the quantity, number, type or distribution of items/services that will be ordered or required by this Agreement. 3.3 i1 The procedure for obtaining Work under this Agreement is outlined in Exhibit A — Scope of Services attached hereto. ❑ ❑ Other Exhibit/Attachment: 3.4 • The County reserves the right to specify in each Request for Quotations: the period of completion; collection of liquidated damages in the event of late completion; and the Price Methodology selected in 4.1. 4. THE AGREEMENT SUM. n The County shall pay the Contractor for the performance of this Agreement based on Work performed pursuant to the quoted price offered by the Contractor in response to a specific Request for Quotations and pursuant to the Price Methodology in Section 4.1 I1111 Contractor's quoted prices for time and material shall be based on Exhibit B- Fee Schedule. Payment will be made upon receipt of a proper invoice and upon approval by the County's Contract Administrative Agent/Project Manager, and in compliance with Chapter 218, Fla. Stats., otherwise known as the "Local Government Prompt Payment Act". n Payment will be made upen Fcecipt of a Contract Administrative Agent/Project Manager, and in compliance with Chapter 218, Fla. Stats., 4.1 Price Methodology (as selected below): ❑■ Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the County to the contractor; and, as a business practice there are no hourly or material invoices presented, rather, the contractor must perform to the satisfaction of the County's project manager before payment for the fixed price contract is authorized. [ime and Materials: The County agrees to pay the contractor for the amount of labor time spent by the contractor's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's markup). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. Page 2 of 33 Multi-Contractor Award Agreement[2021_ver.1] i12 f installation price per ton, delivery price per package or carton, etc.). The invoice must identify the unit price and the number of units received (no contractor inventory or cost verification). 472 4.3 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of the Agreement. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of"laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. 4.4 The County, or any duly authorized agents or representatives of the County, shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Payment Application, Change Order, or Work Directive Change. 4-6 n Section 112.061 Fla. Stats. Mileage $9-44 75-peke Breakfast $6-99 ' $•11.00 Dinner $19.00 Airfare Actual ticket cost limited to tourist or coach class faro Rental car vehicles cap of no more than $150.00 per night Racking Actual cost of parking Taxi or Airport Limousine Actual cost of either taxi or airport limousine Agreement. 5. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. Collier County, Florida as a political subdivision of the State of Florida, is exempt from the payment of Florida sales tax to its vendors under Chapter 212, Florida Statutes, Certificate of Exemption # 85-8015966531 C. Page 3 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO lbC12 6. NOTICES. All notices from the County to the Contractor shall be deemed duly served if mailed or emailed to the Contractor at the following: Company Name: Coastal Concrete Products, LLC dba Coastal Site Development Address: 7742 Alico Road Ft. Myers, FL 33912 Authorized Agent: David E. Torres, Manager Attention Name & Title: Telephone: (239) 208-4079 E-Mail(s): David@torrescompanies.com/maguiar@coastalconcreteproducts.com All Notices from the Contractor to the County shall be deemed duly served if mailed or emailed to the County to: Board of County Commissioners for Collier County, Florida Division Director: Kari Hodgson Division Name: Solid and Hazardous Waste Management Division Address: 3339 Tamiami Trail East Naples, Florida 34112 Administrative Agent/PM: Taylor Sawatzky, Project Manager Telephone: (239) 252-5333 E-Mail(s): Taylor.Sawatzky@colliercountyfl.gov The Contractor and the County may change the above mailing address at any time upon giving the other party written notification. All notices under this Agreement must be in writing. 7. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a partnership between the County and the Contractor or to constitute the Contractor as an agent of the County. 8. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, F.S., all permits necessary for the prosecution of the Work shall be obtained by the Contractor. The County will not be obligated to pay for any permits obtained by Subcontractors. Payment for all such permits issued by the County shall be processed internally by the County. All non-County permits necessary for the prosecution of the Work shall be procured and paid for by the Contractor. The Contractor shall also be solely responsible for payment of any and all taxes levied on the Contractor. In addition, the Contractor shall comply with all rules, regulations and laws of Collier County, the State of Florida, or the U. S. Government now in force or hereafter adopted. The Contractor agrees to comply with all laws governing the responsibility of an employer with respect to persons employed by the Contractor. Page 4 of 33 Multi-Contractor Award Agreement[2021_ver.1] 16C12 9. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any manner whatsoever, County facilities for any improper, immoral or offensive purpose, or for any purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation, or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the event of such violation by the Contractor or if the County or its authorized representative shall deem any conduct on the part of the Contractor to be objectionable or improper, the County shall have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24) hours after receiving notice of such violation, conduct, or practice, such suspension to continue until the violation is cured. The Contractor further agrees not to commence operation during the suspension period until the violation has been corrected to the satisfaction of the County. 10. TERMINATION. Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be the sole judge of non-performance. In the event that the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the Agreement Amount earned through the date of termination. The Contractor shall not be entitled to any other or further recovery against the County, including, but not limited to, any damages or any anticipated profit on portions of the services not performed. 11. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race, sex, color, creed or national origin. 12. INSURANCE. The Contractor shall provide insurance as follows: A. n Commercial General Liability: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, $2,000,000 aggregate for Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. B. n Business Auto Liability: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership. C. n Workers' Compensation: Insurance covering all employees meeting Statutory Limits in compliance with the applicable state and federal laws. The coverage must include Employers' Liability with a minimum limit of$ 1,000,000 for each accident. D-❑ • Page 5 of 33 Multi-Contractor Award Agreement[2021_ver.1] 1 6 C 1 r U +-Coverage shall have minimum limits of$ per claim. Special Requirements: Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Current, valid insurance policies meeting the requirement herein identified shall be maintained by Contractor during the duration of this Agreement. The Contractor shall provide County with certificates of insurance meeting the required insurance provisions. Renewal certificates shall be sent to the County thirty (30) days prior to any expiration date. Coverage afforded under the policies will not be canceled or allowed to expire until the greater of: thirty (30) days prior written notice, or in accordance with policy provisions. Contractor shall also notify County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non- renewal or material change in coverage or limits received by Contractor from its insurer, and nothing contained herein shall relieve Contractor of this requirement to provide notice. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 13. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, whether resulting from any claimed breach of this Agreement by Contractor, any statutory or regulatory violations, or from personal injury, property damage, direct or consequential damages, or economic loss, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 13.1 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, County and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the County or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 14. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the County by the Solid and Hazardous Waste Management Division 15. CONFLICT OF INTEREST. Contractor represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the Page 6 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO 1 6 C1 performance of services required hereunder. Contractor further represents that no persons having any such interest shall be employed to perform those services. 16. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the following component parts, all of which are as fully a part of the Agreement as if herein set out verbatim: Contractor's Proposal, Insurance Certificate(s), 0 Exhibit A Scope of Services, n Exhibit B Fee Schedule, REP/ ITB/■ Other Invitation for Qualification (IFQ) #20-7789 including Exhibits, Attachments and Addenda/Addendum, n subsequent quotes and corresponding contract documents, 7 Exhibit C 1 Public Paymcnt Bond, ❑ Exhibit C 2 Public Performance Bond, • Exhibit D - Release and Affidavit Form, ■ Exhibit E — Form of Contract Application for Payment, ■ Exhibit F - Change Order, ■ Exhibit G - Certificate of Substantial Completion, n Exhibit H -Certificate of Final Completion, n Exhibit I - Warranty, and n Other Exhibit/Attachment: 17. APPLICABILITY. Sections corresponding to any checked box (U) expressly apply to the terms of this Agreement. 18. SUBJECT TO APPROPRIATION. It is further understood and agreed by and between the parties herein that this Agreement is subject to appropriation by the Board of County Commissioners. 19. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and/or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any Agreement held by the individual and/or firm for cause. 20. COMPLIANCE WITH LAWS. By executing and entering into this Agreement, the Contractor is formally acknowledging without exception or stipulation that it agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to this Agreement, including but not limited to those dealing with the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended; taxation, workers' compensation, equal employment and safety including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, if applicable, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Page 7 of 33 Multi-Contractor Award Agreement[2021_ver.11 S 1 6 CI Naples, FL 34112-5746 Telephone: (239) 252-8999 Email: PublicRecordReq_uestAcolliercountvfLgov The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 21. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages and agrees to the successful Contractor extending the pricing, terms and conditions of this solicitation or resultant Agreement to other governmental entities at the discretion of the successful Contractor. 22. 1 1 provide Payment and Performance Bonds. &-: When required 14y Owner, the Contractor sh.a+l furnisha Performance and/or Payment Bond prior to commencing performance, for the full amount of the Work, which shall act as a construction or renovation project performed by the Contractor. The bonds shall be furnished using the forms prescribed in Exhibit "C 1" and Exhibit "C 2". , its right to do business in the State of Florida, terminates or it ceases to meet the Page 8 of 33 Multi-Contractor Award Agreement[2021_ver.1] S 16C12 , 23. • LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to Proceed to be issued by the Owner. Contractor shall commence the work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. The Work shall be substantially completed within the time specified in the Request for Quotation/Scope of Work. The date of substantial completion of the Work (or designated portions thereof) is the date certified by the Owner when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. The Work shall reach final completion and be ready for final acceptance by Owner within the time specified in the Request for Quotation/Scope of Work. Owner and Contractor recognize that since time is of the essence for any work under this Agreement, Owner will suffer financial loss if the Work is not substantially completed within the time specified in the Request for Quotation. Should Contractor fail to substantially complete the Work within the specified time period, Owner shall be entitled to assess as liquidated damages, but not as a penalty, the amount specified in the Request for Quotation/Scope of Work for each calendar day thereafter until substantial completion is achieved. The Project shall be deemed to be substantially completed on the date the Owner issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to substantially complete the Work in a timely manner. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. 24. n PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in excess of thirty (30) days, the Contractor may request to receive Progress Payments. Subsequent to the first payment, Contractor must provide Owner with a fully executed Release and Affidavit in the form attached hereto as Exhibit"D" as a condition precedent to release of each progress payment. All applications for payment, whether for full payment or a progress payment shall be in writing, and in substantially the form attached hereto as Exhibit "E." 25. PAYMENTS WITHHELD. Owner may decline to approve any application for payment, or portions thereof, because of defective or incomplete work, outstanding punchlist items, subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due to Contractor under this Agreement or any other Agreement between Owner and Contractor, Page 9 of 33 Multi-Contractor Award Agreement[2021_ver.1] (CAO I6C12 to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence indicating probable fling of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents. If any conditions described above are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other Agreement between Contractor and Owner. 26. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from specifications shall be approved in writing by Owner in advance. 27. Ui CONTRACT TIME AND TIME EXTENSIONS. A. Time is of the essence in the performance of any Work under this Agreement and Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and materialmen, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's supplies and contractors. B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. C. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 28. I■J CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, Page 10 of 33 Multi-Contractor Award Agreement[2021_ver.1] €A:(2)1 16C12 and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any modifications to this Agreement shall be in compliance with the County's Procurement Ordinance and Procurement Procedures in effect at the time such modifications are authorized. A Change Order in the form attached as Exhibit "F" to this Agreement, shall be issued and executed promptly after an Agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 29. n CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean. 30. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on County projects who are neat, clean, well-groomed and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The County may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Collier County projects is not in the best interest of the County. 31. n TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish to the County the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the County. 32. 0 PROTECTION OF WORK. A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or anyone for whom Contractor is legally liable is responsible for any loss or damage to the Work, or other work or materials of the County or County's separate contractors, Contractor shall be charged with the same, and any monies necessary to replace such loss or damage shall be deducted from any amounts due Contractor. B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. C. Contractor shall not disturb any benchmark established by the County with respect to the Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally liable, disturbs the County's benchmarks, Contractor shall immediately notify the County. The County shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by the County associated therewith. Page 11 of 33 Multi-Contractor Award Agreement[2021_ver.1] (AO 16c12 33. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner is obligated to act to prevent threatened damage, injury or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Owner determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 34. n COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such designated portion) is substantially complete and request that Owner issue a Certificate of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner does not consider the Work (or designated portion) substantially complete, the Owner shall notify Contractor in writing giving the reasons therefor. If Owner considers the Work (or designated portion) substantially complete, Owner shall prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit G, which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punchlist of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punchlist. Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Owner will make such inspection and, if Owner finds the Work acceptable and fully performed under the Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit H, recommending that on the basis of Owner's observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Final payment shall not become due and payable until Contractor submits: A. The Release and Affidavit in the form attached as Exhibit "D." B. Consent of Surety (if applicable) to final payment. C. If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. D. The warranty in the form attached as Exhibit "I". Page 12 of 33 Multi-Contractor Award Agreement[2021_ver.1] ICAO I. CI Owner reserves the right to inspect the Work and make an independent determination as to the acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment shall not become due and payable. 35. 0 WARRANTY. Contractor expressly warrants that the goods, materials and/or equipment covered by this Agreement will conform to the requirements as specified, and will be of satisfactory material and quality production, free from defects, and sufficient for the purpose intended. Goods shall be delivered free from any security interest or other lien, encumbrance or claim of any third party. Any services provided under this Agreement shall be provided in accordance with generally accepted professional standards for the particular service. These warranties shall survive inspection, acceptance, passage of title and payment by the County. Contractor further warrants to the County that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after final completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from the County. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. These warranties are in addition to those implied warranties to which the County is entitled as a matter of law. 36. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect. 37. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this Agreement in compliance with the Procurement Ordinance, as amended, and Procurement Procedures. 38. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision-making authority and by County's staff person who would make the presentation of any settlement reached during negotiations to County for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision-making authority and by County's staff person who would make the presentation of any settlement reached at mediation to County's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 39. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. Page 13 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO 1 6 C 1 2 40. ❑ KEY PERSONNEL. The Contractor's personnel and many the performance of the Agreement. The Contractor shall assign as many people as necessary to complete the services on a timely basis, and each person assigned shall be available for an amount of time adequate to meet the required service dates. The Contractor shall not change Key Personnel unle,e the following conditions arc met: (1) Proposed replacements have substantially in advance as possible. The Contractor shall make commercially reasonable efforts to notify Collier County within seven (7) days of the change. The County retains final approval of proposed replacement personnel. ❑■ AGREEMENT STAFFING. The Contractor's personnel and management to be utilized for this Agreement shall be knowledgeable in their areas of expertise. The County reserves the right to perform investigations as may be deemed necessary to ensure that competent persons will be utilized in the performance of the Agreement. The Contractor shall assign as many people as necessary to complete required services on a timely basis, and each person assigned shall be available for an amount of time adequate to meet required services. 41. ■ ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any of the Contract Documents, the terms of solicitation the Contractor's Proposal, and/or the County's Board approved Executive Summary, the Contract Documents shall take precedence. n the terms of any of the Contract Documents and/or the County's Board approved Executive Summary, the terms of the Agreement shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved by application of the Supplemental Conditions, if any, or the Agreement, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at County's discretion. 42. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of the County. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the County's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward the County. 43. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shall be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance Page 14 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO 16C12 and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e- mail (DL-FMOPS@colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of$500 per incident. 44. n SAFETY. All Contractors and subcontractors performing service for Collier County are required and shall comply with all Occupational Safety and Health Administration (OSHA), State and County Safety and Occupational Health Standards and any other applicable rules and regulations. Also, all Contractors and subcontractors shall be responsible for the safety of their employees and any unsafe acts or conditions that may cause injury or damage to any persons or property within and around the work site. Collier County Government has authorized the Occupational Safety and Health Administration (OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of inspection of any Contractor's work operations. This provision is non-negotiable by any division/department and/or Contractor. All applicable OSHA inspection criteria apply as well as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow OSHA onto a project that is being performed on Collier County Property. Collier County, as the owner of the property where the project is taking place shall be the only entity allowed to refuse access to the project. However, this decision shall only be made by Collier County's Risk Management Division Safety Manager and/or Safety Engineer. (Intentionally left blank-signature page to follow) Page 15 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO 16C1 `?. IN WITNESS WHEREOF, the parties hereto, by an authorized person or agent, have executed this Agreement on the date and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS COLLIER OUNTY, FLORIDA Crystal K. Kinzel, Clerk of Court& Comptroller By: i By: P N TAY R , Chair Dated: S 2 I (SEAL) At est as t hairman's Coastal Concrete Products, LLC dba Contractor's Vle ses:►rr?(1V. Coastal Site Development Contractor t•. �4�:��Li it/rW/7/7 By: Contractor's First Witness Signature David E. T rres - Manager 0.12-1,(o tk M, 1,1141/ka f TType/print signature and titleT TT-ype/tint witness nameT ontr Storrs Second Witness Kih,,•ktk v Type/print wittfess name Se%ved as or and Legality: L. Cou ty Attorney. PrintName Page 16 of 33 Multi-Contractor Award Agreement[2021_ ,r,1 • 'Ao 1 6 C1 Exhibit A Scope of Services n following this page (pages through 3 ) fl this exhibit is not applicable Page 17 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO i 6 tint s IFQ#20-7789"Designated Driveway Contractor Services EXHIBIT A SCOPE OF SERVICES BACKGROUND The Solid&Hazardous Waste Management Division of the Public Utilities Department is responsible for ensuring that collection and disposal services are provided throughout Collier County in a safe and efficient manner. There are more than 300 dead-end streets in Collier County that do not allow for safe turn-around of waste collection vehicles or large emergency vehicles. In most cases,these large vehicles must back down the street to the nearest intersection or back onto private property creating an unsafe condition or damage to private property. The intent of this Agreement is to protect the public and private property by providing turn-around capability on dead-end streets for solid waste collection vehicles by constructing reinforced designated driveways. Designated driveways are property owner-approved reinforced private driveways intended to create safe,designated turn-around areas for solid waste collection vehicles where no turn-around access areas exist. County designated driveway specifications are provided as an attachment to this solicitation. DETAILED SCOPE OF WORK 1. General Requirements The Contractor shall be a Certified General Contractor, Certified Building Contractor, or Certified Underground Utility and Excavation Contractor with the State of Florida. Certification must be current to perform any work under the resultant Contract. Contractor must also be licensed to operate in Collier County. The Contractor and all employees shall comply with applicable Federal,State and Local laws and regulations. 2. Quoting Requirements When the County determines a need for services,a summary of work,technical specifications,etc.will be provided to all selected Contractors, along with a line item quote schedule for providing an all-inclusive lump sum quote. The County's Project Manager will set the required response time for each project,but Contractors will be given a minimum of ten(10)business days to provide a quote.Other projects may require a longer quoting period to allow for proper coordination. The work under this Agreement will be for projects with a value up to$200,000. The Contractors pricing shall be all-inclusive and include,but not be limited to,labor,equipment,supplies,permits,rock,debris excavation,limerock,mobilization,Maintenance of Traffic(MOT),piping,silt fence and any other materials required to properly complete the project.Note that each quote schedule may have a set amount designated by the County's Project Manager for an Owner's Allowance line item to be included. This line item is not a guaranteed amount of money to the Contractor(see"Owner's Allowance"Section 4 below). Completion time and the collection of liquidated damages may be specified in the Request for Quotation(RFQ). Reconstruction of a driveway project shall not exceed a seven(7)business day schedule per single driveway,unless additional time is approved in writing by the County's Project Manager or Designee. The Contractors shall make arrangements(if necessary)with the County's Project Manager or Designee to properly inspect the project site subsurface conditions prior to quote submission. Any required rock or debris excavation shall be included in the lump sum quote. 3. Commencement of Work Work shall not commence until a Work Order/Purchase Order and Notice to Proceed is issued as well as a fully executed and recorded Right of Entry(ROE)Form provided by the County's Project Manager or Designee. The Contractor will be responsible for notifying all residents using a County supplied letter at least twenty-four hours before the start of construction. Page 1 of 3 Exhibit A-Scope of Services (CAC)) 16C The Contractor shall obtain and maintain all required permits or licenses necessary for the prosecution of the work prior to the start of construction. Permits may include, but not be limited to: Collier County Right-of-Way, Exotic and/or Vegetation Removal Permit,and Southwest Florida Water Management District Permit.Payment for all such permits issued by the County shall be processed internally by the County. All non-County permits necessary for the prosecution of the work shall be procured and paid for by the Contractor. 4. Owner's Allowance It shall be at the sole discretion of the County's Project Manager or Designee to determine if and when the Owner's Allowance may be invoiced against by the Contractor.Owner's Allowance shall be billed at Time and Material. Hourly rates are applicable only to Owner's Allowance.Rate Schedule found in Exhibit B-Fee Schedule of this Agreement. Material markup shall not exceed 15%. Contractor must provide backup documentation for all items exceeding$500.No markup shall be applied to sales tax and/or freight. Subcontractor markup shall not exceed 10%. A copy of the Subcontractor invoice must be provided. Material markup shall not be allowed against a Subcontractor's material. Subcontractor hourly rate shall not exceed the Contractor's hourly rate. 5. Work Performance The Contractor shall provide all labor, materials, equipment, supplies, permits and project schedules to complete the entire construction of the awarded project. The County reserves the right to request additional information from the Contractor for clarification on all site-specific construction documents and invoices submitted. Any and all utility relocates that are deemed necessary to complete the project are the responsibility of the Contractor, at no additional cost to the County. A video and digital picture of each project site must be submitted by the Contractor to the County's Project Manager or Designee prior to the start of construction. A video and digital picture of the project site after construction shall be provided upon the Contractor's submittal for Final Completion approval of the project. The method of providing the required media shall be determined by the County Project Manager or Designee. At the County Project Manager's discretion,the Contractor may also be required to submit a video and digital picture of the progress work being performed at the project site at any time.All required videos and digital pictures of the project sites submitted by the Contractor shall become property of the County upon submission. The Contractor shall coordinate and be responsible for all project required testing and inspections, at no additional cost to the County.Testing may include,but not be limited to: Florida Limerock Bearing Ratio(LBR)Testing;Concrete Cylinder Testing and Density Testing. Inspections may include, but not be limited to: County Road Maintenance and/or Right-of-Way permit inspection requirements. All testing and inspection results shall be provided to the County's Project Manager or Designee within twenty-four(24)hours after the report has been issued to the Contractor. The Contractor will be responsible for watering sod for a period of sixty(60) days after installation. 6. Safety It is the Contractor's sole responsibility for safety in the work zone. Contractor shall provide work zone signage, cones, barricades or barrels,arrow panels,flagging personnel and Stop/Slow Paddles,where necessary,as required by law or the Board of County Commissioners(BCC). The Contractor shall run operations in strict accordance with Occupational Safety and Health Administration(OSHA)regulations and the manufacturer's safety requirements. MOT shall be in accordance with Florida Department of Transportation(FDOT)and Collier County Procedure. The County's Project Manager or Designee will be responsible for providing a copy of the Collier County Procedure to the Contractor by internal request of the Risk Management Division.Contractor shall be required to provide Maintenance of Traffic or Temporary Control Certification.If the Contractor is subcontracting MOT,they shall submit the subcontractor's certification. High-visibility clothing or vests with retro-reflectorized striping must always be worn by all employees working within Collier County Rights-of Way (See exception below). This includes personnel that may visit the "work zone" temporarily, such as management and/or Contractors. The American National Standard for High-Visibility Safety Apparel and Headwear (ANSI/ISEA 107-2004)or the most current edition,Class 2 or Class 3 garments are required for daytime use. Page 2 of 3 Exhibit A-Scope of Services d` I6Ci2 • American National Standards Institute/International Safety Equipment Association(ANSI/ISEA)Class 2 or 3 Vests, T-shirts or similarly labeled garments depending on time of day. • A Class 3 garment is mandatory for use by flagging personnel during any hours of darkness, including during inclement weather situations,where conditions may create hours of darkness during normal daylight conditions. • Exception: When other industry apparel safety standards require workers to wear apparel that is inconsistent with Federal, State or County requirements such as OSHA,ANSI, ISEA,etc.,the other standards may prevail. However, apparel must still meet high visibility color requirements of fluorescent lime-green or fluorescent orange only and must be maintained in good condition and replaced as necessary. 7. Clean-Up The Contractor shall be responsible for removing all debris from the project site. The Contractor shall keep the premises free of debris and unusable materials resulting from their work and as work progresses,or upon request by the County's Project Manager or Designee. 8. Damages Carelessness by the Contractor resulting in damage to turf,curbs,sidewalks,pavement or structures,mailboxes,appurtenances, etc. shall be repaired or replaced by the Contractor to the satisfaction of the County's Project Manager or Designee at no additional cost to the County,and damages shall be repaired or replaced within seventy-two(72)hours from the occurrence of the damage. 9. Warranty The Contractor shall professionally perform to the industry standards and to the requirements in this solicitation and subsequent contractual documents. The Contractor shall warrant their work for one(1)year following final acceptance by the County. Page 3 of 3 Exhibit A-Scope of Services 1'., Cl Exhibit B Fee Schedule n following this page (pages through 1 ) Il this exhibit is not applicable Page 18 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO. 16C . ` Coastal Coastal Concrete Site Development Products A Division of Coastal Concrete Products, LLC RATES FOR TIME AND MATERIAL COLLIER COUNTY CONTRACT DESIGNATED DRIVEWAYS CONTRACT 1/13/21 UPDATE Labor Charges—Per Hour Project Manager $105 Superintendent $85 Foreman (Concrete, Grading or Underground) $70 Equipment Operator $65 Underground Crew Labor $60 Concrete Crew Labor $60 Grading Crew Labor $55 MOT Labor $55 Other Labor $55 Equipment Charges(excluding Operator)—Per Hour Excavator-Large (50,000Ibs+) $140 Excavator-Medium (20,000-50,0001bs) $100 Excavator-Mini (0-20,0001bs) $80 Loader-Skid Steer(Bobcat) $75 Loader—Medium (Kubota R520/Komatsu 95) $95 Loader—Full Size(Komatsu 250 or larger) $110 Dump Truck—18cyd $75 Bulldozer $105 Motor Grader $130 Dewatering Pump—2 &3" $45 Dewatering Pump—4" $55 Dewatering Pump—6" $75 Dewatering Pump—8" $85 Trench Box $70 Plate Compactor $50 Small Roller $65 Full Size Roller $80 MOT Device (cone,sign, drum, etc) $0.50 Listed models are for reference only. Equivalent equipment of a different brand shall be billed at same rate. Materials provided to be billed and marked up as per Collier County contract standards. Use of subcontractors shall also meet Contract requirements for allowed markup. Rental equipment shall be billed at cost plus a ten percent markup. C1 2 Exhibit C-1 ■ this exhibit is not applicable PUBLIC PAYMENT BOND Bond No. Contract No. KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and , as Surety, located at (Business Address) are held and firmly bound to as Oblige in the sum of ($ ) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the _day of , 20_ with Oblige for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect sureties' obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.0592. In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20_, the name of under-signed representative, pursuant to authority of its governing body. Page 19 of 33 Multi-Contractor Award Agreement[2021_ver.1] I6Ct Signed, sealed and delivered in the presence of: PRINCIPAL: By: Witnesses as to Principal Name: Its: STATE OF COUNTY OF The foregoing instrument was acknowledged before me by means of ❑ physical presence or ❑ online notarization, this of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary Public-State of Florida) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: ATTEST: SURETY: (Printed Name) (Business Address) (Authorized Signature) Witness as to Surety (Printed Name) OR Page 20 of 33 Multi-Contractor Award Agreement[2021_ver.1] I C t As Attorney in Fact (Attach Power of Attorney) Witnesses (Business Address) (Printed Name) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me by means of ❑ physical presence or ❑ online notarization, this of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary Public-State of Florida) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: Page 21 of 33 Multi-Contractor Award Agreement[2021_ver.11 16C12 n this exhibit is not applicable EXHIBIT C-2 PUBLIC PERFORMANCE BOND Bond No. Contract No. KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and , as Surety, located at (Business Address) are held and firmly bound to , as Oblige in the sum of ($ ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the_day of 20 , with Oblige for in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract, and 2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Oblige; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or to work or to the specifications. Page 22 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO 16Cl ? This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this Performance bond regardless of the number of suits that may be filed by Oblige. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20_, the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. Signed, sealed and delivered in the presence of: PRINCIPAL: By: Witnesses as to Principal Name: Its: STATE OF COUNTY OF The foregoing instrument was acknowledged before me by means of ❑ physical presence or ❑ online notarization, this of _20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary Public-State of Florida) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: Page 23 of 33 Multi-Contractor Award Agreement[2021_ver.1] A 1) 16 C1 ATTEST: SURETY: (Printed Name) (Business Address) (Authorized Signature) Witness as to Surety (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) Witnesses (Business Address) (Printed Name) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me by means of ❑ physical presence or ❑ online notarization, this of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary Public-State of Florida) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: Page 24 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO. 1 6 C I I this exhibit is not applicable EXHIBIT D RELEASE AND AFFIDAVIT FORM COUNTY OF ( STATE OF ( Before me, the undersigned authority, personally appeared _who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final]Application for Payment No. CONTRACTOR BY: Witness ITS: DATE: Witness [Corporate Seal] STATE OF COUNTY OF The foregoing instrument was acknowledged before me by means of ❑ physical presence or ❑ online notarization, this of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary Public-State of Florida) NAME: (Legibly Printed) Notary Public, State of (AFFIX OFFICIAL SEAL) Commissioner No.: Page 25 of 33 Multi-Contractor Award Agreement[2021_ver.1] S 16C12 ❑ this exhibit is not applicable EXHIBIT E FORM OF CONTRACT APPLICATION FOR PAYMENT (County Project Manager) Bid No. (County Department) Project No. Collier County Board of County Commissioners (the OWNER) or Collier County Water-Sewer District(the OWNER) Application Date FROM: (Contractor's Representative) Payment Application No. (Contractor's Name) for Work accomplished through the Date: (Contractor's Address) RE: (Project Name) Original Contract Time: Original Contract Amount: $ Revised Contract Time: Total Change Orders to Date $ Revised Contract Amount $ Total value of Work Completed Retainage @ 10% thru [insert date] $ and stored to Date $ Retainage @ _% after [insert date] $ Less previous payment (s) $ Percent Work completed to Date: % AMOUNT DUE THIS Percent Contract Time completed to Date % APPLICATION: $ Liquidated Damages to be Accrued $ ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2)title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the revised contract and shall be incorporated into a future Change Order: By CONTRACTOR: (Contractor's Name) (Signature) DATE: (Type Name &Title) (shall be signed by a duly authorized representative of CONTRACTOR) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended: By Design Professional : (DP's Name) (Signature) DATE: (Type Name&Title) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved: By OWNER'S Project Manager: (Signature) DATE: (Type Name and Title) Page 26 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO 16C12 ❑ this exhibit is not applicable EXHIBIT F CHANGE ORDER ❑ Contract Modification ❑Work Order Modification Contract#: Change#: Purchase Order#: Project#: Contractor/Firm Name: Project Name: Project Manager Name: Department: Original Contract/Work Order Amount Original BCC Approval Date; Agenda Item # Current BCC Approved Amount Last BCC Approval Date; Agenda Item # Current Contract/Work Order Amount SAP Contract Expiration Date (Master) Dollar Amount of this Change #DIV/0! Total Change from Original Amount Revised Contract/Work Order Total $ 0.00 #DIV/0! Change from Current BCC Approved Amount Cumulative Changes $ 0.00 #DIV/0! Change from Current Amount Completion Date, Description of the Task(s)Change,and Rationale for the Change Notice to Proceed Original Last Approved Revised Date Date Completion Date Date Includes this change) #of Days Added Select Tasks ❑Add new task(s) ❑ Delete task(s) ❑ Change task(s) ❑Other(see below) Provide a response to the following: 1.)detailed and specific explanation/rationale of the requested change(s)to the task(s)and /or the additional days added(if requested);2.)why this change was not included in the original contract;and,3.) describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if needed. Prepared by: Date: (Project Manager Name and Division) Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the same terms and conditions as contained in the contract/work order indicated above,as fully as if the same were stated in this acceptance. The adjustment, if any, to the Contract shall constitute a full and final settlement of any and all claims of the Contractor /Vendor/ Consultant/Design Professional arising out of or related to the change set forth herein, including claims for impact and delay costs. Accepted by: Date: (Contractor/Vendor/Consultant/Design Professional and Name of Firm, if project applicable) Approved by: Date: (Design Professional and Name of Firm, if project applicable) Approved by: Date: (Procurement Professional Page 27 of 33 Multi-Contractor Award Agreement[2021_ver.1] CA© C i `a ❑ this exhibit is not applicable EXHIBIT G CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. ENGINEER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial completion applies to all Work under the Contract documents or to the following specified parts thereof: To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the contract documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all- inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. Page 28 of 33 Multi-Contractor Award Agreement[2021_ver.1] CAO) 1GCi2 The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: RESPONSIBILITIES: OWNER: CONTRACT OR: The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20_ Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on , 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER By: Type Name and Title Page 29 of 33 Multi-Contractor Award Agreement[2021_ver.1] 6C . n this exhibit is not applicable EXHIBIT H CERTIFICATE OF FINAL COMPLETION OWNER'S Project No. ENGINEER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Final completion applies to all Work under the Contract documents. To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be finally complete in accordance with the contract documents on: DATE OF FINAL COMPLETION The warranty in Exhibit I is attached to and made a part of this Certificate: Page 30 of 33 Multi-Contractor Award Agreement[2021_ver.1] 1 C Executed by Design Professional on , 20_ Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Final Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Final Completion on 20 OWNER By: Type Name and Title Page 31 of 33 Multi-Contractor Award Agreement[2021_ver.1] 16C12 E this exhibit is not applicable EXHIBIT I WARRANTY In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the contract either directly performed by the CONTRACTOR or at the express request of the CONTRACTOR by a SUBCONTRACTOR or CONSULTANT. Project Name: Date of Final Completion: Name and Address of CONTRACTOR: CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of all defects of materials and workmanship for a period of one year from the DATE OF FINAL COMPLETION. The undersigned party further agrees that it will, at its own expense, replace and/or repair all defective work and materials and all other work damaged by any defective work upon written demand by the COUNTY. It is further understood that further consideration for this warranty and guaranty is the consideration given for the requirement pursuant to the general conditions and specifications under which the contract was let that such warranty and guaranty would be given. This warranty and guaranty is in addition to any other warranties or guaranties for the work performed under the contract and does not constitute a waiver of any rights provided pursuant to Florida Statutes, Chapter 95, et seq. DATE: CONTRACTOR BY: Attest: Page 32 of 33 Multi-Award Agreement 2017.006 Ver.l ,CAO 1 6 C I 2 Other Exhibit/Attachment Description: ❑ following this page (pages through _) 0 this exhibit is not applicable Page 33 of 33 Multi-Award Agreement 2017.006 Ver.I CAO 16C1 ? Client#: 67237 COACO6 ACORD.,, CERTIFICATE OF LIABILITY INSURANCE DATEIMMWDD/YYYY) 4/26/2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder In lieu of such endorsement(s). PRODUCER NAMEACT Courtney Butler Acrisure dba Gulfshore Ins SWF PHONE 239 430-7534 FAX (A/C,No,Ext): (A/C,No): 4100 Goodlette Road N E-MAIL cbutler@gulfshoreinsurance.com Naples, 34103 ADDRESS: �g 239 261 FL46 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:American Zurich Insurance Company 40142 INSURED INSURER B:American Guarantee&Liability Ins Co 26247 Coastal Concrete Products LLC Markel American Insurance Company 28932 7742 Alico Rd INSURER C: P Y Fort Myers, FL 33912-6021 INSURER D: INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. LT RR TYPE OF INSURANCE INSR WWI POLICY NUMBER /YPOLICY EFF POLICY EXP LIMITS _ (MMlDD/YYY1� (MM/DDYYY) A X COMMERCIAL GENERAL LIABILITY X X GL0743477702 11/17/2020 11/17/2021 EACH �� C OCCURRENCE $2,000,000 PRE CLAIMS-MADE X OCCUR MISES�EaLEDnce) $300,000 MED EXP(Any one person) $5,000 PERSONAL&ADV INJURY $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $4,000,000 POLICY X PR LOC PRODUCTS-COMP/OP AGG $4,000,000 OTHER: $ B AUTOMOBILE LIABILITY X X BAP743477802 11/17/2020 11/17/2021 COMBcINEDdent)SINGLE LIMIT $1,000,000 (Ea ac X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident)'$ AUTOS ONLY AUTOS X AUTOS ONLY X NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY (Per accident) B X UMBRELLA LIAB X OCCUR AUC757740402 11/17/2020 11/17/2021 EACH OCCURRENCE $4,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $4,000,000 DED X RETENTION$O $ B WORKERS COMPENSATION X WC675866500 11/17/2020 11/17/2021 X STATUTE EMPLOYERS'LIABILITY Y/N STATUTE �R ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? y N f A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 C Leased/Rented MKLM3IM0050766 11/17/2020 11/17/2021 $400,000 Lim$2,500 Ded Equipment DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Project#20-7789, Designated Driveway Contractor Services Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County,OR, Collier County Government, OR, Collier County are included as Additional Insured on a primary and noncontributory basis with regards to General Liability only as required by written contract per form UGL1175FCW 0413, includes ongoing and completed operations,Waiver of Subrogation in favor of Additional (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION Collier CountyBoard of CountySHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Commissioners ACCORDANCE WITH THE POLICY PROVISIONS. 3295 Tamiami Trail E Naples, FL 34112 AUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 2 The ACORD name and logo are registered marks of ACORD #S1686736/M1653549 STY 16C12 DESCRIPTIONS (Continued from Page 1) Insured(s) per form UGL925BCW 1201.Additional Insured in regards to Auto Liability only as required by written contract per form CA2048 1013.Waiver of Subrogation regards to Auto Liability per form CA0444 1013.Waiver of Subrogation in regards to Workers Compensation only as required by written contract per form WC000313 0484. Umbrella Follows Form. **30 Days Notice of Cancellation,except 10 days for nonpayment' SAGITTA 25.3(2016/03) 2 of 2 #S1686736/M1653549 I6CI. z Additional Insured —Automatic — Owners, Lessees Or ZURICH Contractors Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff.Date of End. Producer No. Add'I.Prem Return Prem. GL0743477702 11/17/2020 11/17/2021 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Named Insured: Coastal Concrete Products LLC Address (including ZIP Code): This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part A. Section II—Who Is An Insured is amended to include as an additional insured any person or organization whom you are required to add as an additional insured on this policy under a written contract or written agreement. Such person or organization is an additional insured.only with respect to liability for"bodily injury", "property damage" or"personal and advertising injury"caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf, in the performance of your ongoing operations or "your work" as included in the "products-completed operations hazard", which is the subject of the written contract or written agreement. However, the insurance afforded to such additional insured: 1. Only applies to the extent permitted by law; and 2. Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds,the following additional exclusion applies: This insurance does not apply to: "Bodily injury", "property damage" or"personal and advertising injury" arising out of the rendering of, or failure to render, any professional architectural, engineering or surveying services including: a. The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders,change orders or drawings and specifications;or b. Supervisory, inspection,architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment,training or monitoring of others by that insured, if the"occurrence"which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional architectural, engineering or surveying services. U-GL-1175-F CW(04/13) Page 1 of 2 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. 16C12 C. The following is added to Paragraph 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit of Section IV— Commercial General Liability Conditions: The additional insured must see to it that: 1. We are notified as soon as practicable of an "occurrence"or offense that may result in a claim; 2. We receive written notice of a claim or"suit'as soon as practicable; and 3. A request for defense and indemnity of the claim or "suit" will promptly be brought against any policy issued by another insurer under which the additional insured may be an insured in any capacity. This provision does not apply to insurance on which the additional insured is a Named Insured if the written contract or written agreement requires that this coverage be primary and non-contributory. D. For the purposes of the coverage provided by this endorsement: 1. The following is added to the Other Insurance Condition of Section IV — Commercial General Liability Conditions: Primary and Noncontributory insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured provided that: a. The additional insured is a Named Insured under such other insurance;and b. You are required by written contract or written agreement that this insurance be primary and not seek contribution from any other insurance available to the additional insured. 2. The following paragraph is added to Paragraph 4.b.of the Other Insurance Condition of Section IV—Commercial General Liability Conditions: This insurance is excess over: Any of the other insurance, whether primary, excess, contingent or on any other basis, available to an additional insured, in which the additional insured on our policy is also covered as an additional insured on another policy providing coverage for the same "occurrence", offense, claim or"suit". This provision does not apply to any policy in which the additional insured is a Named Insured on such other policy and where our policy is required by a written contract or written agreement to provide coverage to the additional insured on a primary and non- contributory basis. E. This endorsement does not apply to an additional insured which has been added to this policy by an endorsement showing the additional insured in a Schedule of additional insureds, and which endorsement applies specifically to that identified additional insured. F. With respect to the insurance afforded to the additional insureds under this endorsement, the following is added to Section III—Limits Of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the written contract or written agreement referenced in Paragraph A.of this endorsement; or 2. Available under the applicable Limits of Insurance shown in the Declarations, whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. All other terms and conditions of this policy remain unchanged. U-GL-1175-F CW(04/13) Page 2of2 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. 16C12 Waiver Of Subrogation (Blanket) Endorsement ZURICH Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff.Date of End. Producer Add'I.Prem Return Prem. GL0743477702 11/17/2020 11/17/2021 $ $ THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: If you are required by a written contract or agreement,which is executed before a loss,to waive your rights of recovery from oth- ers,we agree to waive our rights of recovery. This waiver of rights shall not be construed to be a waiver with respect to any other operations in which the insured has no contractual interest. U-GL-925-B CW(12/01) Page 1 of 1 16Cl2 POLICY NUMBER: BAP 7434778-02 COMMERCIAL AUTO CA 20 48 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s) who are "insureds"for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: COASTAL CONCRETE PRODUCTS LLC Endorsement Effective Date: SCHEDULE Name Of Person(s)Or Organization(s): ANY PERSON OR ORGANIZATION TO WHOM OR TO WHICH YOU ARE REQUIRED TO PROVIDE ADDITIONAL INSURED STATUS OR ADDITIONAL INSURED STATUS ON A PRIMARY, NON-CONTRIBUTORY BASIS, IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT EXECUTED PRIOR TO LOSS, EXCEPT WHERE SUCH CONTRACT Information required to complete this Schedule, if not shown above,will be shown in the Declarations. Each person or organization shown in the Schedule is an "insured" for Covered Autos Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Paragraph A.1. of Section II — Covered Autos Liability Coverage in the Business Auto and Motor Carrier Coverage Forms and Paragraph D.2. of Section I — Covered Autos Coverages of the Auto Dealers Coverage Form. CA 20 48 10 13 ©Insurance Services Office, Inc., 2011 Page 1 of 1 16Cl2 POLICY NUMBER: BAP 7 4 3 4 7 7 8-02 COMMERCIAL AUTO CA 04 44 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: COASTAL CONCRETE PRODUCTS LLC Endorsement Effective Date: SCHEDULE Name(s) Of Person(s)Or Organization(s): ALL PERSONS AND/OR ORGANIZATIONS THAT ARE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT WITH THE INSURED, EXECUTED PRIOR TO THE ACCIDENT OR LOSS, THAT WAIVER OF SUBROGATION BE PROVIDED UNDER THIS POLICY. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident" or the "loss" under a contract with that person or organization. CA 04 44 10 13 ©Insurance Services Office, Inc., 2011 Page 1 of 1 16C . 2 Client#: 67237 COACO6 ACORDTM CERTIFICATE OF LIABILITY INSURANCE DATE(MM1DD/YYYY)4M26M2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder In lieu of such endorsement(s). PRODUCER CONTACT Courtney Butler Acrisure dba Gulfshore Ins SWF PHONE _ FAX Ext):239 430-7534 (A/C,No); 4100 Goodlette Road N E-MAIL cbutler@gulfshoreinsurance.com Naples, 34103 ADDRESS: �g 239 261 FL46 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:American Zurich Insurance Company 40142 INSURED INSURER B;American Guarantee&Liability Ins Co 26247 Coastal Concrete Products LLC 7742 Alico Rd INSURER C:Markel American Insurance Company 28932 Fort Myers, FL 33912-6021 INSURER D INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSRT TYPE OF INSURANCE INSRL WVD POLICY NUMBER (SUBR MM/DD//YY EYYYY) (MM/DDIYYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY X X GL0743477702 11/17/2020 11/17/2021 EACH OCCURRENCE $2,000,000 D CLAIMS-MADE X OCCUR PREMISES(Ea occurrence) $300,000 MED EXP(Any one person) $5,000 PERSONAL&ADV INJURY $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $4,000,000 _ POLICY X JJECOT LOC PRODUCTS-COMP/OP AGG $4,000,000 OTHER: $ B AUTOMOBILE LIABILITY X X BAP743477802 11/17/2020 11117/2021 E°yBcINdeDnt SINGLE LIMIT $1,000,000 X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X AUTOS ONLY X NON-OWNED PROPERTY DAMAGE AUTOS ONLY (Per accident) B X UMBRELLA LIAB X OCCUR AUC757740402 11/17/2020 11117/2021 EACH OCCURRENCE $4,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $4,000,000 DED X,RETENTION$0 B WORKERS COMPENSATION X WC675866500 11/17/2020 11/17/2021 X STATUTE ERH AND EMPLOYERS'LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE Y/N E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? Y N/A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E-L.DISEASE-POLICY LIMIT $1,000,000 C Leased/Rented MKLM3IM0050766 11/17/2020 11117/2021 $400,000 Lim$2,500 Ded Equipment I DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Project#20-7789,Designated Driveway Contractor Services Collier County Board of County Commissioners,OR, Board of County Commissioners in Collier County,OR, Collier County Government,OR, Collier County are included as Additional Insured on a primary and noncontributory basis with regards to General Liability only as required by written contract per form UGL1175FCW 0413, includes ongoing and completed operations,Waiver of Subrogation in favor of Additional (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION Collier CountyBoard of CountySHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Commissioners ACCORDANCE WITH THE POLICY PROVISIONS. 3295 Tamiami Trail E Naples, FL 34112 AUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 2 The ACORD name and logo are registered marks of ACORD #51686736/M1 653549 STY 16Cl2 DESCRIPTIONS (Continued from Page 1) Insured(s) per form UGL925BCW 1201.Additional Insured in regards to Auto Liability only as required by written contract per form CA2048 1013.Waiver of Subrogation regards to Auto Liability per form CA0444 1013.Waiver of Subrogation in regards to Workers Compensation only as required by written contract per form WC000313 0484. Umbrella Follows Form. **30 Days Notice of Cancellation,except 10 days for nonpayment** SAGITTA 25.3(2016/03) 2 of 2 #51686736/M1653549 16C12 0 Additional Insured — Automatic — Owners, Lessees Or ZURICH Contractors Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff.Date of End. Producer No. Add'I.Prem Return Prem. GL0743477702 11/17/2020 11/17/2021 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Named Insured: Coastal Concrete Products LLC Address (including ZIP Code): This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part A. Section II —Who Is An Insured is amended to include as an additional insured any person or organization whom you are required to add as an additional insured on this policy under a written contract or written agreement. Such person or organization is an additional insured only with respect to liability for"bodily injury", "property damage" or"personal and advertising injury"caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf, in the performance of your ongoing operations or "your work" as included in the "products-completed operations hazard", which is the subject of the written contract or written agreement. However, the insurance afforded to such additional insured: 1. Only applies to the extent permitted by law; and 2. Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or failure to render, any professional architectural, engineering or surveying services including: a. The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or b. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional architectural, engineering or surveying services. U-GL-1175-F CW(04/13) Page 1 of 2 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. 16C12 C. The following is added to Paragraph 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit of Section IV — Commercial General Liability Conditions: The additional insured must see to it that: 1. We are notified as soon as practicable of an "occurrence"or offense that may result in a claim; 2. We receive written notice of a claim or"suit"as soon as practicable; and 3. A request for defense and indemnity of the claim or "suit" will promptly be brought against any policy issued by another insurer under which the additional insured may be an insured in any capacity. This provision does not apply to insurance on which the additional insured is a Named Insured if the written contract or written agreement requires that this coverage be primary and non-contributory. D. For the purposes of the coverage provided by this endorsement: 1. The following is added to the Other Insurance Condition of Section IV — Commercial General Liability Conditions: Primary and Noncontributory insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured provided that: a. The additional insured is a Named Insured under such other insurance; and b. You are required by written contract or written agreement that this insurance be primary and not seek contribution from any other insurance available to the additional insured. 2. The following paragraph is added to Paragraph 4.b. of the Other Insurance Condition of Section IV—Commercial General Liability Conditions: This insurance is excess over: Any of the other insurance, whether primary, excess, contingent or on any other basis, available to an additional insured, in which the additional insured on our policy is also covered as an additional insured on another policy providing coverage for the same "occurrence", offense, claim or"suit". This provision does not apply to any policy in which the additional insured is a Named Insured on such other policy and where our policy is required by a written contract or written agreement to provide coverage to the additional insured on a primary and non- contributory basis. E. This endorsement does not apply to an additional insured which has been added to this policy by an endorsement showing the additional insured in a Schedule of additional insureds, and which endorsement applies specifically to that identified additional insured. F. With respect to the insurance afforded to the additional insureds under this endorsement, the following is added to Section III—Limits Of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the written contract or written agreement referenced in Paragraph A. of this endorsement; or 2. Available under the applicable Limits of Insurance shown in the Declarations, whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. All other terms and conditions of this policy remain unchanged. U-GL-1175-F CW(04/13) Page 2 of 2 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. 16C12 Waiver Of Subrogation (Blanket) Endorsement ZURICH Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff.Date of End. Producer Add'l.Prern Return Preen. GL0743477702 11/17/2020 11/17/2021 $ THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: If you are required by a written contract or agreement,which is executed before a loss,to waive your rights of recovery from oth- ers,we agree to waive our rights of recovery. This waiver of rights shall not be construed to be a waiver with respect to any other operations in which the insured has no contractual interest. U-GL-925-B CW(12/01) Page 1 of 1 t6 POLICY NUMBER: BAP 7434778-02 COMMERCIAL AUTO CA20481013 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s) who are "insureds" for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: COASTAL CONCRETE PRODUCTS LLC Endorsement Effective Date: SCHEDULE Name Of Person(s) Or Organization(s): ANY PERSON OR ORGANIZATION TO WHOM OR TO WHICH YOU ARE REQUIRED TO PROVIDE ADDITIONAL INSURED STATUS OR ADDITIONAL INSURED STATUS ON A PRIMARY, NON-CONTRIBUTORY BASIS, IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT EXECUTED PRIOR TO LOSS, EXCEPT WHERE SUCH CONTRACT Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Each person or organization shown in the Schedule is an "insured" for Covered Autos Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Paragraph A.1. of Section II — Covered Autos Liability Coverage in the Business Auto and Motor Carrier Coverage Forms and Paragraph D.2. of Section I — Covered Autos Coverages of the Auto Dealers Coverage Form. CA 20 48 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 1 6 C 1 2 POLICY NUMBER: BAP 7 4 3 4 7 7 8-02 COMMERCIAL AUTO CA04441013 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: COASTAL CONCRETE PRODUCTS LLC Endorsement Effective Date: SCHEDULE Name(s) Of Person(s)Or Organization(s): ALL PERSONS AND/OR ORGANIZATIONS THAT ARE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT WITH THE INSURED, EXECUTED PRIOR TO THE ACCIDENT OR LOSS, THAT WAIVER OF SUBROGATION BE PROVIDED UNDER THIS POLICY. i Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident" or the "loss" under a contract with that person or organization. CA 04 44 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1