The URL can be used to link to this page

Agenda 10/13/2020 Item #16C 4 (Agmt. #19-7525 - EBL Partners, LLC)10/13/2020 EXECUTIVE SUMMARY Recommendation to Award EBL Partners LLC, under Agreement #19-7525, in the amount of $499,779.15 on a Purchase Order to Provide the Labor, Material and Equipment to modify the existing Electrical Switchgear in the J1 Electric Room, so t hat a Tri Star Docking Station can be installed that will enable the J1-J2 Jail Facilities to be connected to a Portable Generator as backup in the event of an emergency. This is a Surtax Project. OBJECTIVE: To ensure the J1 (Old Jail) and J2 (Administration) Jail Facilities maintain compliance with the Florida Building Code and remain safe for the Collier County Sheriff’s Office (CCSO) employees as well as inmates by enabling the facilities to be connected to a portable generator to support its 24 hour a day, 7 day a week operation during emergencies.. CONSIDERATIONS: Florida Building Code 408.4.2 requires that Correctional Institutions be supported with backup generator power in the event of an emergency. The CCSO’s J1 -J2 Jail facility is currently equipped with partial back-up power from J3 (New Jail) and requires fitting a docking station to enable a portable generator use so that all of the Emergency Systems can be energized in the event of a loss of Electrical Power. Collier County retained the services of Atkins North American Inc. to prepare bid documents for this Project. This Project was put out on Bid Sync to all of the General Contractors that are on Contract # 19 - 7525. The following General Contractors submitted Bids and the engineer of record recommendation is to award the work to the lowest bid: Contractor Quote EBL Partners $499,779.15 Capitol Contractors LLC $596,891.29 Compass Constructions Inc $621,866.00 FISCAL IMPACT: Funding in the amount of $499,779.15 is available within the Infrastructure Sales Tax Fund (318) - Project 50184. LEGAL CONSIDERATIONS: This item has been reviewed by the County Attorney, is approved as to form and legality, and requires majority vote for approval. - JAK GROWTH MANAGEMENT IMPACT: There is no growth management impact associated with this Executive Summary. ADVISORY BOARD RECOMMENDATION: The Collier County J1 and J2 Jail Generator project was reviewed and approved as eligible for sales tax funding by the Collier County Infrastructure Surtax Citizens Oversight Committee as Agenda item 2B on March 4, 2020. RECOMMENDATION: That the Board of County Commissioners approve a purchase order to EBL Partners in the amount of $499,779.15 to provide the Labor, Material and Equipment to furnish and install the modifications to the existing J1 Electrical Switch Gear and furnish and install one Tri Star Docking Station so that a Portable Generator can be connected to power the J1- J2 Jail Facility. Prepared by: Thomas Orr, Project Manager, Facilities Management Division 16.C.4 Packet Pg. 1721 10/13/2020 ATTACHMENT(S) 1. RFQ Scope of Work (PDF) 2. J1 J2 Generator Phase 1 EBL Schedule of Values (PDF) 3. J1 J2 Phase 1 Generator Final Quote Tabulation (PDF) 4. EBL Bid (PDF) 5. Compass Bid (PDF) 6. Capitols Bid (PDF) 7. [Linked] 19-7525 EBL Partners, LLC Contract (PDF) 8. Checklist CC-J1 and J2 Jail Generator Validated - 03_04_2020 Signed (PDF) 9. Bond (PDF) 10. Naples Jail 1 Jail 2 - Opinion of Cost (PDF) 11. Collier Jail Atkins Probable Construction Cost Phase 1 (PDF) 12. Collier County Naples Jail Electrical Bids recommendation (PDF) 16.C.4 Packet Pg. 1722 10/13/2020 COLLIER COUNTY Board of County Commissioners Item Number: 16.C.4 Doc ID: 12980 Item Summary: Recommendation to Award EBL Partners LLC, under Agreement #19-7525, in the amount of $499,779.15 on a Purchase Order to Provide the Labor, Material and Equipment to modify the existing Electrical Switchgear in the J1 Electric Room, so that a Tri Star Docking Station can be installed that will enable the J1 - J2 Jail Facilities to be connected to a Portable Generator as backup in the event of an emergency. Meeting Date: 10/13/2020 Prepared by: Title: – Facilities Management Name: Kathleen Sibert 09/01/2020 12:10 PM Submitted by: Title: Director - Facilities Management – Facilities Management Name: Damon Grant 09/01/2020 12:10 PM Approved By: Review: Facilities Management Damon Grant Director - Facilities Completed 09/01/2020 12:15 PM Public Utilities Operations Support Joseph Bellone Additional Reviewer Completed 09/01/2020 12:17 PM Procurement Services Opal Vann Level 1 Purchasing Gatekeeper Completed 09/01/2020 12:30 PM Procurement Services Sandra Herrera Additional Reviewer Completed 09/02/2020 2:54 PM Public Utilities Department Dan Rodriguez Additional Reviewer Completed 09/18/2020 10:14 AM Public Utilities Department Drew Cody Level 1 Division Reviewer Completed 09/18/2020 11:20 AM Public Utilities Department George Yilmaz Level 2 Division Administrator Review Completed 09/29/2020 6:51 PM Office of Management and Budget Debra Windsor Level 3 OMB Gatekeeper Review Completed 09/30/2020 8:36 AM County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 09/30/2020 1:27 PM Office of Management and Budget Laura Zautcke Additional Reviewer Completed 10/02/2020 9:09 AM Budget and Management Office Ed Finn Additional Reviewer Completed 10/02/2020 5:17 PM County Manager's Office Sean Callahan Level 4 County Manager Review Completed 10/05/2020 10:56 AM Board of County Commissioners MaryJo Brock Meeting Pending 10/13/2020 9:00 AM 16.C.4 Packet Pg. 1723 16.C.4.a Packet Pg. 1724 Attachment: RFQ Scope of Work (12980 : J1 - J2 Electrical Switchgear) 16.C.4.a Packet Pg. 1725 Attachment: RFQ Scope of Work (12980 : J1 - J2 Electrical Switchgear) 16.C.4.a Packet Pg. 1726 Attachment: RFQ Scope of Work (12980 : J1 - J2 Electrical Switchgear) 16.C.4.a Packet Pg. 1727 Attachment: RFQ Scope of Work (12980 : J1 - J2 Electrical Switchgear) 16.C.4.a Packet Pg. 1728 Attachment: RFQ Scope of Work (12980 : J1 - J2 Electrical Switchgear) New Generators for Buildings J1 & J2 Phase 1 & 2 Item No. Description Unit Quantity Unit Cost Item Total 1 Mobilization ‐ Bond LS 1 8,986.54$ 8,986.54$ 2 Order and Delivery of Temp. MDP LS 1 50,917.09$ 50,917.09$ 3 General Conditions LS 1 5,281.20$ 5,281.20$ 4 Sitework LS 1 6,912.00$ 6,912.00$ 5 Paint and Stucco LS 1 2,160.00$ 2,160.00$ 6 Misc. Plumbing LS 1 1,944.00$ 1,944.00$ 7 Electrical LS 1 423,578.32$ 423,578.32$ Total Lump Sum 499,779.15$ 499,779.15$ 1482 Rail Head Blvd., Naples Fl 34110 16.C.4.b Packet Pg. 1729 Attachment: J1 J2 Generator Phase 1 EBL Schedule of Values (12980 : J1 - J2 Electrical Switchgear) DATE SENT:June 1,2020QUOTE DUE DATE: May 29,2020SITE VISIT: Not MandatoryNew Generator for Building J1 & J2 Phase 1 of 2 AWARD CRITERIA: Lowest Base BidSummary Description Capital Contractors, LLC EBL Partners Compass Construction IncBase Bid as per Bid Documents and attached Scope of Work. $596,891.29 LS 499,779.15$ LS $621,866.00 LSTotals596,891.29$ $499,779.15 621,866.00$ Documents Verified Yes Yes YesPlease fill out and sign this form along with your proposal. No proposal will be considered unless the RFQ form is properly signed.New Generator for Building J1 & J2 Phase 1 of 2 June 25, 2020 at 3:00 PM16.C.4.cPacket Pg. 1730Attachment: J1 J2 Phase 1 Generator Final Quote Tabulation (12980 : J1 - J2 Electrical Switchgear) 16.C.4.dPacket Pg. 1731Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.d Packet Pg. 1732 Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.dPacket Pg. 1733Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.d Packet Pg. 1734 Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.d Packet Pg. 1735 Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.d Packet Pg. 1736 Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.d Packet Pg. 1737 Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.dPacket Pg. 1738Attachment: EBL Bid (12980 : J1 - J2 Electrical Switchgear) DATE SENT: April 23rd, 2020 BID DUE DATE: May 21st, 2020 at 3:00 PM SITE VISIT: Available Anytime During Business Hours New Generators for Buildings J1 & J2 Phase 1 of 2 AWARD CRITERIA: Lowest Base Bid For Providing the Electrical Work and Equipment as per the Bid Dcouments. Summary Description Lump Sum Base Bid BASE BID AS PER BID DOCUMENTS AND ATTACHED SCOPE OF WORK. Contractor is to legally dispose of all the HM Doors, HM Frames and Hardware that the County does not want to keep TOTAL BASE BID 621,866.00$ New Generators for Buildings J1 & J2 Phase 1 of 2 Due: May 21st, 2020 at 3:00PM Please fill out and sign this form along with your reqired forms. No submittal will be considered unless the all form is properly signed. Vendor Signature: _____________________________________________________________________________ Print Name:__Doug Oliver, President_______________________________________________________________ Company Name: ___Compass Construction, Inc.___________________________________ Date: _6/25/20_____ 16.C.4.e Packet Pg. 1739 Attachment: Compass Bid (12980 : J1 - J2 Electrical Switchgear) 16.C.4.fPacket Pg. 1740Attachment: Capitols Bid (12980 : J1 - J2 Electrical Switchgear) MULTI -CONTRACTOR AWARD AGREEMENT # 19-7525 for Annual Agreement for General Contractor Services THIS AGREEMENT, made and entered into on this a� day of 20Rhrized by and between EBL Partners LLC au to do business in the State of Florida, whose business address is 1482 Rail Head Blvd Naples Florida 34110 , (the "Contractor") and Collier County, a political subdivision of the State of Florida, (the "County" or "Owner"): WITNESSETH: 1. AGREEMENT TERM. The Agreement shall be for a three (3 )year period, commencing FE] upon the date of Board approval ❑ and terminating three (3 ) year(s) from that date or until all outstanding R Purchase Order(s) ❑ Work Order(s) issued prior to the expiration of the Agreement period have been completed or terminated. The County may, at its discretion and with the consent of the Contractor, renew the Agreement under all of the terms and conditions contained in this Agreement for one (� ) additional three ( 3 year(s) periods. The County shall give the Contractor written notice of the County's intention to renew the Agreement term prior to the end of the Agreement term then in effect. The County Manager, or his designee, may, at his discretion, extend the Agreement under all of the terms and conditions contained in this Agreement for up to one hundred and eighty (180) Jays. The County Manager, or his designee, shall give the Contractor written notice of the County's intention to extend the Agreement term prior to the end of the Agreement term then in effect. 2. COMMENCEMENT OF SERVICES. The Contractor shall commence the work upon issuance of a OPurchase Order ❑■ Notice to Proceed. 3. STATEMENT OF WORK, The Contractor shall provide services in accordance with the terms and conons of ❑ ❑ 0 Other Request for Qualification R( FQ ) # 19-7525 including all Attachment(s), Exhibit(s) and Addenda and the Contractor's proposal referred to herein and made an integral part of this Agreement. ❑� The Contractor shall also provide services in accordance with Exhibit A — Scope of Services attached hereto. 3.1 This Agreement contains the entire understanding between the parties and any modifications to this Agreement shall be mutually agreed upon in writing by the Parties, in compliance with the County's Procurement Ordinance, as amended, and Procurement Procedures in effect at the time such services are authorized. Page 1 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 C�v 3.2 The execution of this Agreement shall not be a commitment to the Contractor to order any minimum or maximum amount. The County shall order items/services as required but makes no guarantee as to the quantity, number, type or distribution of items/services that will be ordered or required by this Agreement. 3.3 Lw The procedure for obtaining Work under this Agreement is outlined in Exhibit A —Scope of Services attached hereto. 3.4 L�mj The County reserves the right to specify in each Request for Quotations: the period of completion; collection of liquidated damages in the event of late completion; and the Price Methodology selected in 4.1. 4. THE AGREEMENT SUM. 0 The County shall pay the Contractor for the performance of this Agreement based on Work performed pursuant to the quoted price offered by the Contractor in response to a specific Request for Quotations and pursuant to the Price Methodology in Section 4.1. ❑ queted ePayment will be made upon receipt of a proper invoice and upon approval by the County's Contract Administrative Agent/Project Manager, and in compliance with Chapter 218, Fla. Stats., otherwise known as the "Local Government Prompt Payment Act". - - ■ ■ - 1 - r 4.1 Price Methodology (as selected below): � Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the County to the contractor; and, as a business practice there are no hourly or material invoices presented, rather, the contractor must perform to the satisfaction of the County's project manager before payment for the fixed price contract is authorized. W Time and Materials: The County agrees to pay the contractor for the amount of labor time spent by the contractor's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's markup). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. Page 2 of 33 Multi -Contractor Award Agreement 2017,006 Ver.1 pj Unit Price: The County agrees to pay a firm total fixed price (inclusive of all costs, including labor, materials, equipment, overhead, etc.) for a repetitive product or service delivered (Len installation price per ton, delivery price per package or carton, etc.). The invoice must identify the unit price and the number of units received (no contractor inventory or cost verification). 4.2 Any County agency may obtain services under this Agreement, provided sufficient funds are included in their budget(s). 4.3 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of the Agreement. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of itlaches)I as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. 5. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. Collier County, Florida as a political subdivision of the State of Florida, is exempt from the payment of Florida sales tax to its vendors under Chapter 212, Florida Statutes, Certificate of Exemption # 85-8015966531 C. Page 3 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 CAv 6. NOTICES. All notices from the County to the Contractor shall be deemed duly served if mailed or emailed to the Contractor at the following: Company Name: EBL Partners, LLC Address: 1482 Rail Head Blvd Naples, Florida 34110 Authorized Agent: Attention Name & Title: Telephone: E-Mail(s): Paul Benson (239) 431-5003 benson@eblpartners.com All Notices from the Contractor to the County shall be deemed duly served if mailed or emailed to the County to: Board of County Commissioners for Collier County, Florida Division Director: Damon Grant Division Name: Facilities Management Division Address: 3335 Tamiami Trail East, Suite 101 Naples, Florida 34112 Administrative Agent/PM: Miguel Carballo Telephone: (239) 252-8380 E-Mail(s): Miguel Carballo@colliercountyfl.gov The Contractor and the County may change the above mailing address at any time upon giving the other party written notification. All notices under this Agreement must be in writing. PARTNERSHIP. Nothing herein contained shall create or be construed as creating a partnership between the County and the Contractor or to constitute the Contractor as an agent of the County. 8. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, F.S., all permits necessary for the prosecution of the Work shall be obtained by the Contractor. The County will not be obligated to pay for any permits obtained by Subcontractors. Payment for all such permits issued by the County shall be processed internally by the County. All non -County permits necessary for the prosecution of the Work shall be procured and paid for by the Contractor. The Contractor shall also be solely responsible for payment of any and all taxes levied on the Contractor. In addition, the Contractor shall comply with all rules, regulations and laws of Collier County, the State of Florida, or the U. S. Government now in force or hereafter adopted. The Contractor agrees to comply with all laws governing the responsibility of an employer with respect to persons employed by the Contractor. 9. NO IMPROPER USE, The Contractor will not use, nor suffer or permit any person to use in any manner whatsoever, County facilities for any improper, immoral or offensive purpose, or for any purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation, Page 4 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the event of such violation by the Contractor or if the County or its authorized representative shall deem any conduct on the part of the Contractor to be objectionable or improper, the County shall have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24) hours after receiving notice of such violation, conduct, or practice, such suspension to continue until the violation is cured. The Contractor further agrees not to commence operation during the suspension period until the violation has been corrected to the satisfaction of the County. 10. TERMINATION. Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be the sole judge of non-performance. In the event that the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the Agreement Amount earned through the date of termination. The Contractor shall not be entitled to any other or further recovery against the County, including, but not limited to, any damages or any anticipated profit on portions of the services not performed. 11. NO DISCRIMINATION. The Contractor agrees sex, color, creed or national origin. that there shall be no discrimination as to race, 12. INSURANCE. The Contractor shall provide insurance as follows: A. � Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per Occurrence, $ 2,000,000 aggregate for Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. B. � Business Auto Liability: Coverage shall have minimum limits of $1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non -Owned Vehicles and Employee Non -Ownership. C. � Workers' Compensation: Insurance covering all employees meeting Statutory Limits in compliance with the applicable state and federal laws. The coverage must include Employers' Liability with a minimum limit of $1,000,000 for each accident. Special Requirements: Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Page 5 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 CAS Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Current, valid insurance policies meeting the requirement herein identified shall be maintained by Contractor during the duration of this Agreement. The Contractor shall provide County with certificates of insurance meeting the required insurance provisions. Renewal certificates shall be sent to the County thirty (30) days prior to any expiration date. Coverage afforded under the policies will not be canceled or allowed to expire until the greater of: thirty (30) days prior written notice, or in accordance with policy provisions. Contractor shall also notify County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non - renewal or material change in coverage or limits received by Contractor from its insurer, and nothing contained herein shall relieve Contractor of this requirement to provide notice. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 13. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, whether resulting from any claimed breach of this Agreement by Contractor, any statutory or regulatory violations, or from personal injury, property damage, direct or consequential damages, or economic loss, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 13.1 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, County and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the County or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 14. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the County by the Faces Management Division 15, CONFLICT OF INTEREST. Contractor represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. Contractor further represents that no persons having any such interest shall be employed to perform those services. Page 6 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 16. COMPONENT PARTS OF THIS AGREEMENT, This Agreement consists of the following component parts, all of which are as fully a part of the Agreement as if herein set out verbatim: Contractor's Proposal, Insurance Certificate(s), 0 Exhibit A Scope of Services, ❑ Cvhihit B Coo SGhedwie, ❑ R f t I-TB/n Other Request for Qualification # 19-7525 , including Exhibits, Attachments and Addenda/Addendum, ❑ subsequent yeses, ❑i Fo Exhibit C-1 Public Payment Bond, 0 Exhibit C-2 Public Performance Bond, Exhibit D - Release and Affidavit Form, R Exhibit E — Form of Contract Application for Payment, F Exhibit F - Change Order, 0 Exhibit G - Certificate of Substantial Completion, Exhibit H - Certificate of Final Completion, F Exhibit I - Warranty, and F Other Exhibit/Attachment: Exhibit I- Federal Grant Provisions 17. APPLICABILITY. Sections corresponding to any checked box (�) expressly apply to the terms of this Agreement. 18, SUBJECT TO APPROPRIATION. It is further understood and agreed by and between the parties herein that this Agreement is subject to appropriation by the Board of County Commissioners. 19. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and/or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any Agreement held by the individual and/or firm for cause. 20. COMPLIANCE WITH LAWS. By executing and entering into this Agreement, the Contractor is formally acknowledging without exception or stipulation that it agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to this Agreement, including but not limited to those dealing with the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended; taxation, workers' compensation, equal employment and safety including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and.Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112=5746 Telephone: (239) 252=8383 Page 7 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 Cp,O The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 21. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages and agrees to the successful Contractor extending the pricing, terms and conditions of this solicitation or resultant Agreement to other governmental entities at the discretion of the successful Contractor. 22. 0 BONDS. A. When a construction project is in excess of $200,000, the Contractors) shall be required to provide Payment and Performance' Bonds. B. When required by Owner, the Contractor shall furnish a Performance and/or Payment Bond prior to commencing performance, for the full amount of the Work, which shall act as a security guaranteeing the performance of the Contractor's work and the payment by the Contractor to any other party(ies) providing labor and/or materials in connection with each construction or renovation project performed by the Contractor. The bonds shall be furnished using the forms prescribed in Exhibit "C-1" and Exhibit "C-2". C. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business in the State of Florida, terminates or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute another bond and surety, both of which shall be subject to the Owner's approval. Page 8 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 cp,0 23. ] LIQUIDATED DAMAGES, The Commencement Date shall be established in the Notice to Proceed to be issued by the Owner` Contractor shall commence the work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date, Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. The Work shall be substantially completed within the time specified in the Request for Quotation/Scope of Work. The date of substantial completion of the Work (or designated portions thereof) is the date certified by the Owner when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. The Work shall reach final completion and be ready for final acceptance by Owner within the time specified in the Request for Quotation/Scope of Work. Owner and Contractor recognize that since time is of the essence for any work under this Agreement, Owner will suffer financial loss if the Work is not substantially completed within the time specified in the Request for Quotation. Should Contractor fail to substantially complete the Work within the specified time period, Owner shall be entitled to assess as liquidated damages, but not as a penalty, the amount specified in the Request for Quotation/Scope of Work for each calendar day thereafter until substantial completion is achieved. The Project shall be deemed to be substantially completed on the date the Owner issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to substantially complete the Work in a timely manner. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If_the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. 24. Q PAYMENTS. (',enerally, the Contractor will be paid upon completion; however, for Work in excess of thirty (3u) days, the Contractor may request to receive Progress Payments. Subsequent to the first payment, Contractor must provide Owner with a fully executed Release and Affidavit in the form attached hereto as Exhibit "D" as a condition precedent to release of each progress payment. All applications for payment, whether for full payment or a progress payment shall be in writing, and in substantially the form attached hereto as Exhibit "E." 25. PAYMENTS WITHHELD. Owner may decline to approve any application for payment, or portions thereofI because of defective or incomplete work, outstanding punchlist items, subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other Agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence indicating probable fling of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the Page 9 of 33 Multi -Contractor Award Agreement 2017,006 Ver.1 unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents. If any conditions described above are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other Agreement between Contractor and Owner. 26, SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from specifications shall be approved in writing by Owner in advance. 27. 0 CONTRACT TIME AND TIME EXTENSIONS. A. Time is of the essence in the performance of any Work under this Agreement and Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and materialmen, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's supplies and contractors. B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. C. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 28. � CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any modifications to this Agreement shall be in compliance with the County's Page 10 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 Cr�.0 Procurement Ordinance and Procurement Procedures in effect at the time such modifications are authorized. A Change Order in the form attached as Exhibit "F" to this Agreement, shall be issued and executed promptly after an Agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders, The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 29. 0 CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean. 30. STANDARDS OF CONDUCT: PROJECT MANAGER SUPERVISOR EMPLOYEES. The Contractor shall employ people to work on County projects who are neat, clean, well-groomed and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The County may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Collier County projects is not in the best interest of the County. 31. Q TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish to the County the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the County. 32. � PROTECTION OF WORK. A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or anyone for whom Contractor is legally liable is responsible for any loss or damage to the Work, or other work or materials of the County or County 's separate contractors, Contractor shall be charged with the same, and any monies necessary to replace such loss or damage shall be deducted from any amounts due Contractor. 3. Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. C. Contractor shall not disturb any benchmark established by the County with respect to the Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally liable, disturbs the County's benchmarks, Contractor shall immediately notify the County. The County shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by the County associated therewith. 33. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner is obligated to act to prevent threatened damage, injury or loss. Page 11 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 cao Contractor shall give the Owner written notice within forty-eight (48) hours after the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Owner determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 34. LW COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such designated portion) is substantially complete and request that Owner issue a Certificate of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner does not consider the Work (or designated portion) substantially complete, the Owner shall notify Contractor in writing giving the reasons therefor. If Owner considers the Work (or designated portion) substantially complete, Owner shall prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit G, which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punchlist of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punchlist. Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Owner will make such inspection and, if Owner finds the Work acceptable and fully performed under the Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit H, recommending that on the basis of Owner's observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Final payment shall not become due and payable until Contractor submits: A. The Release and Affidavit in the form attached as Exhibit "D." B. Consent of Surety (if applicable) to final payment. C. If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. D. The warranty in the form attached as Exhibit "I". Owner reserves the right to inspect the Work and make an independent determination as to the acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment shall not become due and payable. Page 12 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 35. J WARRANTY. Contractor expressly warrants that the goods, materials and/or equipment covered by this Agreement will conform to the requirements as specified, and will be of satisfactory material and quality production, free from defects, and sufficient for the purpose intended. Goods shall be delivered free from any security interest or other lien, encumbrance or claim of any third party. Any services provided under this Agreement shall be provided in accordance with generally accepted professional standards for the particular service. These warranties shall survive inspection, acceptance, passage of title and payment by the County. Contractor further warrants to the County that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected; used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after final completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from the County. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. These warranties are in addition to those implied warranties to which the County is entitled as a matter of law. 36. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect. 37. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this Agreement in compliance with the Procurement Ordinance, as amended, and Procurement Procedures. 38. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision -making authority and by County's staff person who would make the presentation of any settlement reached during negotiations to County for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision -making authority and by County's staff person who would make the presentation of any settlement reached at mediation to County's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44,102, Fla. Stat. 39. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 40. ❑ Page 13 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 pj AGREEMENT STAFFING. The Contractor's personnel and management to be utilized for this Agreement shall be knowledgeable in their areas of expertise. The County reserves the right to perform investigations as may be deemed necessary to ensure that competent persons will be utilized in the performance of the Agreement. The Contractor shall assign as many people as necessary to complete required services on a timely basis, and each person assigned shall be available for an amount of time adequate to meet required services. � ORDER OF PRECEDENCE (Grant Funded). In the event of any conflict between or among the terms of any of the Contract Documents and/or the County's Board approved Executive Summary, the terms of the Agreement shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved by application of the Supplemental Conditions, if any, or the Agreement, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at County's discretion. 42. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of the County. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the County's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward the County. 43. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shall be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their Page 14 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 CAU background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e- mail (DL-FMOPS@colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of $500 per incident. 44. [pi SAFETY. All Contractors and subcontractors performing service for Collier County are required and shall comply with all Occupational Safety and Health Administration (OSHA), State and County Safety and Occupational Health Standards and any other applicable rules and regulations. Also, all Contractors and subcontractors shall be responsible for the safety of their employees and any unsafe acts or conditions that may cause injury or damage to any persons or property within and around the work site. Collier County Government has authorized the Occupational Safety and Health Administration (OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of inspection of any Contractor's work operations. This provision is non-negotiable by any division/department and/or Contractor. All applicable OSHA inspection criteria apply as well as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow OSHA onto a project that is being performed on Collier County Property. Collier County, as the owner of the property where the project is taking place shall be the only entity allowed to refuse access to the project. However, this decision shall only be made by Collier County Is Risk Management Division Safety Manager and/or Safety Engineer. (Intentionally left blank -signature page to follow) Page 15 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 FAO IN WITNESS WHEREOF, the parties hereto, have each, respectively, by an authorized person a agent, have executed this Agreement on the date and year first written above, ATTEST: Crystal K. By: L le By: �� Dated:nu,. Kinzel,,Fylem)yf Courts & Contractor's""Wit'r t..1:,t• 1, LA-'- - 'li�I ( V.�., ' &. ri Contractor's First Witnes s TType/print witness nameV 41 Ad. (l ontractor's Second Witness l?V41 L/Y6CAkQ TType/print witness nameT as t�'13o�m and Legality: County Attorney nt Name BOARD OF CO OMMISSIONERS COLLIER GO , FLO Wil m L. McDaniel Jr. , Chairman EBL Partinirs, LLC Contractor By:�) � Signature A r j ° j7l;gw ^A - TType/print signature and titleT Page 16 of 33 Multi-Conlracior Award Agreement 2017.006 Ver.1 CAO Exhibit A Scope of Services Lip following this page (pages through 6 ) ❑ this exhibit is not applicable Page 17 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 19-7525 "Annual Agreement for General Contractor Services EXHIBIT A SCOPE OF SERVICES 1. Scope of Work 1.1. General Contractors will be responsible for providing complete construction services fora wide range of projects and also responsible for the overall coordination of a project. The General Contractor will provide material, labor, equipment, tools and services necessary for all projects assigned. When necessary, the General Contractor may hire specialized subcontractors to perform all, or some portion of the construction work. 1.2.The General Contractor must be qualified and is directly responsible for 100% of the contracted work including all work performed by the in-house personnel or any subcontractors. In the event the General Contractor does not "self -perform" any or all tasks within the specifications, and utilizes subcontractors, the General Contractor is directly responsible for all supervision, monitoring and compliance with one hundred percent (100%) of meeting schedule, cost, work scope plans and specification quality in the performance of a project for the County. 1.3.The General Contractors may be involved in: 1.3.1. Construction supervision/administration; 1.3.2. New construction; 1.3.3. Renovations/retrofits/remediation; 1.3.4. Site or utility improvements; 1.3.5. Complete or selective demolition; 1.3.6. Estimating cost of future projects; 1.3.7. Coordinating with project consultants; and, 1.3.8. Scheduling work and subcontractors in harmony with the County's operations; 1.3.9. Coordination of design and engineering services. 1.4. The General Contractors' responsibilities may include, but are not limited to: 1.4.1. Hiring various trades to complete a project; 1.4.2. Applying for building permits; 1.4.3. Securing the property; 1 A.4. Providing temporary utilities on site; 1.4.5. Managing personnel on site; and 1.4.6. Disposing and/or recycling of construction waste, monitoring schedules and cash flows, and maintaining accurate records; 1.4.7. Subcontracting design and/or engineering services relative to the work required. The above list is not intended to represent the entire GC portfolio, but rather, a sample of the various responsibilities that a GC may be requested to participate in for a Collier County project. 2. Procedures for Obtaining Work Assignments 2.1. For all projects, the County's Project Manager will follow the procedure outlined below to receive quotes from the General Contractors. EXHIBIT A Page 1 of 6 CAv 2.1.1. A Summary of Work, Project Plans, Technical Specifications, etc. will be provided to all of the Contractors, along with a quote schedule for providing price. The County's Project Manager may assess Liquidated Damages per work assignment. 2.1.2. The County Project Manager will set the required response time for each project, but contractors will be given a minimum of ten (10) business days to provide a quote. Other projects may require longer quoting period to allow for proper coordination. Some projects, urgent in nature, may require a shorter response schedule at the Project Manager's discretion. This period may also include a pre -bid meeting. 2.1.3. Contractors shall provide a lump sum quote, based on the quote schedule provided. The following is an example of a quote schedule that may be required: Item Description Unit Amount Item Cost Number 1 Mobilization Lump Sum 1 $0.00 2 Sitework Lump Sum 1 $0.00 3 Masonry Lump Sum 1 $0.00 4 Structural Lump Sum 1 $0.00 5 Roofing Lump Sum 1 $0.00 6 Plumbing Lump Sum 1 $0.00 7 14VAC Lump Sum 1 $0.00 8 Electrical Lump Sum 1 $0.00 $0.00 9 Owner's Allowance T&M $0.00 Lump Sum Total $0.00 2.1:4. Ancillary charges may be transferred to the County in the actual amount; however, mark-ups will not be allowed. Mark-ups will not be allowed on sales tax, consumer fees or taxes, use and other similar taxes, or fees associated with any work under this Agreement. 2.1.5. The Project Manager will review all of the quotes and may negotiate with the Contractor who submits the lowest quote, if outside of the budget. 2.1.6. All work assignments that exceed $200,000 for any one project, will require Board approval. 2.1.7. Performance and Payment Bonds will be required for projects over $200,000. 2.1.8. Once a contractor is selected for a work assignment, the County's Project Manager will issue a Purchase Order, 2.1.9. The contractor may not begin work until a written Notice to Proceed is issued from the County's Project Manager or designee. 3. General Requirements 3.1. Performance and Payment Bonds: When a work assignment is in excess of $200,000.00, the Contractors) shall be required to provide Performance and Payment, Bonds, in the amount of 100% of the quoted work assignment amount; the costs of which is to be paid by Contractor. If the work assignment will be more than thirty (30) EXHIBIT A Page 2 of 6 CCU days in duration and less than $200,000.00, the County's project manager may request Payment and Performance Bonds. All performance security under the subsequent work assignment shall be continued for a six (6) month period beyond the final completion of the project. 3.2. Progress Payments: For work that will not be completed within a thirty (30) day period, the Contractor may wish to receive Progress Payments. Subsequent to the first Application for Payment, the Contractor shall submit to the County, for their review and approval, a schedule of values based upon the total amount to be paid to the Contractor. The Schedule of Values will be formatted by the Contractor to provide for necessary cost breakdowns of the Work by trade category. After its approval by the Owner, that schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. The first Application for Payment shall be submitted no earlier than thirty (30) days after the issuance of the purchase order and Notice to Proceed. 3.3. Insurance/Disaster Related Repairs: For insurance related repairs/work, the Contractor may be asked to provide an itemized breakdown of materials, labor and associated costs necessary for submittal to Risk Management. ide itemize For disaster related repairs/work, the Contractor may be asked to provan d breakdown of materials, labor and associated costs necessary for submittal to Risk Management. If FEMA related, the Contract will be required to comply with the term and condition in the attached provisions (i.e. Lump Sum Only) and will be defined within the work assignment issued by the County as applicable. 3.4. Equipment Inventory: The Contractors) shall, under no circumstances, remove any equipment containing a County asset sticker, without written authorization from the County staff. The Contractors) shall request that, when replacing equipment, the asset sticker be removed by an appropriate County staff member authorized to adjust equipment inventory records. 3.5. Facility Safety, Security and Standards: The contractor and their subcontractors are required to comply with County Ordinance 2004-52, as amended and all future changes. Background checks are valid for five (5) years and the vendor / subcontractor shall be responsible for all associated costs. The cost is $40.00 per person. At all times, the contractor and their subcontractors must wear the assigned Contractor badge while conducting work on County property. Work assignments must be performed in accordance with standards and guidelines set by the County's Project Manager. The Contractors) will comply with all applicable federal, state and local laws, ordinances, rules and regulations pertaining to the performance of the services requested herein. Any fines levied due to inadequacies, or failure to comply with any requirements, will be the sole responsibility, of the Contractor(s). Any employee or representative of the Contractor(s) found not in conformance with any laws, statutes, rules or regulations will not be allowed on job sites. Violations by a Contractor may constitute cause for immediate termination of the Agreement. The Contractors) shall replace or repair any loss at their cost. The County may withhold payment or make such deductions as it may deem necessary to insure reimbursement for loss or damage to property or persons through negligence of the Contractor and its employees. EXHIBIT A Page 3 of 6 CAO Contractor is expected to understand and comply with all applicable laws and regulations of any applicable governmental entity and Collier County CMA's, Standard Operating Procedures (SOP's) or Job Safety Analysis (JSA's) that that pertain to environmental, health and safety standards and/or work practices applicable to the activities they perform. Contractor must agree that all work must meet or exceed the standards set forth in the Collier County Vertical Construction Standards and Collier County IT Construction Standards (if applicable) unless specifically exempted in writing by Facilities Management Division Representative or designee. The Contractor(s) must comply with Federal and State right -to -know laws if hazardous materials are used. Material Safety Data Sheets (MSDS) will be made available and provided to the County per the County Representative's direction. The Contractor is required to immediately report to the County Representative or designee any spillage or dumping of hazardous material on County property. The Contractor shall bear all costs associated with the cleanup of any such incidents. 3.6. High Security Environments: The successful Contractors) will be asked to work in the Collier County Sheriff Office Correctional Facilities and other areas considered "high security", which require thorough background checks of personnel and tools taken into such Facilities. Additional access and logistical requirements for high security sites may be set at the Project Manager's discretion in the Summary of Work during work assignments. 3.7. Warranty: All new equipment/parts warranty work shall be provided by the original warranty supplier. All warranty responsibility for parts or equipment previously purchased, but still under warranty will continue to be provided by the original warranty supplier until expiration of the warranty period. 3.8. Trouble Calls: Ali trouble calls are initially reported to Facilities Management. If the trouble call involves a warranty item, the County Project Manager shall notify the Contractor, who will then have the responsibility of placing the warranty trouble call with the warranty supplier and tracking the problem until it has been fully remedied. Maintenance of a warranty inventory list for each completed project through the warranty period and the tracking of warranty trouble calls shall be provided by the Contractor at no additional cost to the County. 3.9. Parts and Fixtures: Parts and fixtures shall be new and warranted for a minimum of one (1) year or the standard offered by the manufacturer, whichever is greater, after acceptance of the Project. All labor for repairs shall have a minimum of ninety (90) day warranty. All call backs will be free of charge. No labor will be billed or allowable in the event defective parts were used. An extended warranty and/or service agreement may be purchased through the Contractor from the manufacturer without any markup being charged to the County. 3.10. Express Warranties: EXHIBIT A Page 4 of 6 coo Contractor shall obtain and assign to the County all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to the County that any materials and equipment furnished under the Contract shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract. Contractor further warrants to the County that all materials and equipment furnished under the Contract shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract, Contractor shall correct it promptly after receipt of written notice I rom the County. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, the County may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which the County is entitled as a matter of law. 3.11. Changes in the Work Contractor shall provide Owner with a Time and Material Not to Exceed (T&M NTE) proposal for any changes in the work. The proposal shall include breakdown of Contractor's time, materials and any proposed subcontractor quotes. Invoicing for all T&M NTE work shall include backup documentation of Contractor's time, purchased materials and subcontractor invoices. General Contractors) agree to the following, as pertains to markups on Change Order Work: The mark-up on rental equipment shall not exceed 10% and equipment owned by the contractor utilized on a project will not be charged back to the owner. The mark-up on subcontractors shall not exceed 15%. The mark-up on materials shall not exceed 20%. The Labor rates provided by the Contractor as a part of a change order, relative to labor rates pertaining to changes in the work, are to be fully burdened to include overhead, insurance, profit and use of company owned small tools and equipment. Some work assignments will utilize a fee schedule for labor categories and parts unit pricing. Fee ith schedule rates, which are subject to additions or deletions, will be negotiated wthe selected vendors and will be added to the work assignment in the form of a fee schedule for utilization. 3.12. Compliance with County Risk Management Requirements Contractors will be expected to understand and comply with all applicable laws and regulations of any governmental entity having jurisdiction and Collier County CMA's, Standard Operating Procedures (SOP's) or Job Safety Analysis (JSA's) that that pertain to environmental, health and safety standards and/or work practices applicable to the activities they perform. These include but are not limited to: EXHIBIT A Page 5 of 6 coo • Storage, handling, and use of flammable liquids and hazardous materials. • Storage, handling, and use of compressed gas cylinders. • Periodic safety inspections of equipment and work -site housekeeping. • Use of fall protection while working at heights above 6 feet. • Following electrical safety practices and lock out / tag out procedures. • Proper use of personal protective equipment. • Proper maintenance and use of ladders and other equipment. • Guarding of wall and floor openings, open trenches, and excavations. 4. Applicable Articles The following Articles of the Agreement shall only be applicable for individual projects over $200,000: Article 22. Bonds Article 23, Liquidated Damages Article 24, Payments Article 34. Completion EXHIBIT A Page 6 of 6 ❑ following this page (pages 0 this exhibit is not applicable Exhibit B Fee Schedule through ) Page 18 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 C4O Exhibit C-1 ❑ this exhibit is not applicable KNOW ALL MEN BY THESE PRESENTS: That Principal, and (Business Address) to as Oblige in the sum of ($ ) for the payment whereof we bind ourselves, our representatives, successors and assigns, jointly and severally. Bond No. Contract No. as as Surety, located at are held and firmly bound heirs , executors, personal W HEREAS, Principal has entered into a contract dated as of the _day of 20_ with Oblige for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect sureties' obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.0592. In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. body. IN WITNESS WHEREOF, the above parties have executed this instrument this day of 20_, the name of under -signed representative, pursuant to authority of its governing Page 19 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 Signed, sealed and delivered in the presence of: Witnesses as to Principal STATE OF _ COUNTY OF PRINCIPAL: By: — Name: Its: The foregoing instrument was acknowledged before me this of 20 by as of a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) ATTEST: Witness as to Surety (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: SURETY: (Printed Name) (Business Address) (Authorized Signature) (Printed Name) 9 Page 20 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 As Attorney in Fact (Attach Power of Attorney) Witnesses (Business Address) (Printed Name) (Telephone Number) STATE OF _ COUNTY OF The foregoing instrument was acknowledged before me this as of to me OR has produced My Commission Expires: (AFFIX OFFICIAL SEAL) of Surety, on behalf of Surety. He/She is personally known as identification and who did (did not) take an oath. (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page 21 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 ❑ this exhibit is not applicable EXHIBIT C-2 PUBLIC PERFORMANCE BOND Bond No. Contract No. KNOW ALL MEN BY THESE PRESENTS: That as Principal, and as Surety, located at (Business Address) are held and firmly bound to as Oblige in the sum of ($ ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the _day of )0 , with Oblige for in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract, and 2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Oblige; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or othe, ork to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or to work or to the specifications. Page 22 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 �'f6O This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this Performance bond regardless of the number of suits that may be filed by Oblige. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20_, the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. Signed, sealed and delivered in the presence of : PRINCIPAL: Witnesses as to Principal STATE OF _ COUNTY OF By: _ Name: Its: The foregoing instrument was acknowledged before me this day of 20 by as of behalf f the corporation a , He/She is personally known to me OR has produced did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) corporation, on o as identification and (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page 23 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 ATTEST: Witness as to Surety Witnesses STATE OF _ COUNTY OF (Printed Name) (Business Address) (Authorized Signature) (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) (Business Address) (Printed Name) (Telephone Number) The foregoing instrument was acknowledged before me this day of , 20,_, by _ , as of Surety, on behalf of Surety. He/She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page 24 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 ❑ this exhibit is not applicable EXHIBIT D RELEASE AND AFFIDAVIT FORM COUNTY OF STATE OF (_ Before me, the undersigned authority, personally appeared being duly sworn, deposes and says: who after (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, might be sued or for which a lien or a demand materials, supplies, lands, licenses and other expenses for which Owner against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No, Witness Witness STATE OF COUNTY OF CONTRACTOR BY: ITS: DATE: [Corporate Seal] The foregoing instrument was acknowledged before me this day of as of , a corporation, on behalf of the corporation. He/she is personally known to me or has as identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) NAME: (Signature of Notary) (Legibly Printed) Notary Public, State of Commissioner No.: produced Page 25 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 ❑ this exhibit is not applicable EXHIBIT E FORM OF CONTRACT APPLICATION FOR PAYMENT (County Project Manager) (County Department) Collier County Board of County Commissioners (the OWNER) or Collier County Water -Sewer District (the OWNER) FROM: (Contractor's Representative) (Contractor's Name) (Contractor's Address) RE: Original Contract Time: Revised Contract Time: Retainage @ 10% thru[insert date] Retainage @ __% after [insert date] Percent Work completed to Date: Percent Contract Time completed to Date Liquidated Damages to be Accrued a Bid No. Project No. Application Date Payment Application No. for Work accomplished through the Date: Project Name) Original Contract Amount: $ Total Change Orders to Date $ Revised Contract Amount $ Total value of Work Completed and stored to Date $ Less previous payment (s) $ AMOUNT DUE THIS APPLICATION: $ ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the revised contract and shall be incorporated into a future Change Order: By CONTRACTOR: (Contractor's Name) (Signature) DATE: (Type Name &Title) (shall be signed by a duly authorized representative of CONTRACTOR) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended: By Design Professional DATE: (DP's Name) (Signature) (Type Name &Title) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved: By OWNER'S Project Manager: (Signature) (Type Name and Title) Page 26 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 CAO ❑ this exhibit is not applicable ❑ Contract Modification EXHIBIT F CHANGE ORDER ❑ Work Order Modification Contract #: �� Change #: Purchase Order #: Contractor/Firm Name: Project Manager Name: — Project Name: Department: --� Project #: Original Contract/Work Order Amount Original BCC Approval Date; Agenda Item #'. Current BCC Approved Amount Last BCC Approval Date; Agenda Item # Current Contract/Work Order Amount SAP Contract Expiration Date (Master) Dollar Amount of this Change _ #DIV/0i Total Change from Original Amount Revised Contract/Work Order Total $ 0.00 #DIV/01 Change from Current BCC Approved Amount Cumulative Changes $ 0.00 #DIV/01 Chan e from Current Amount Completion Date, Description of the Tasks) Change, and Rationale for the Change Notice to Proceed � Original Last Approved Revised Date Date Completion Date C� Date Includes this change) # of Days Added Select Tasks ❑ Add new task(s) ❑ Delete task(s) ❑ Change task(s) ❑ Other (see below) Provide a response to the following: 1.) detailed and specific explanation/rationale of the requested change(s) to the task(s) and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.) describe the , t �� , A++n, h a.teqi+i„nai infnrmatinn from the Desian Professional and/or Contractor if needed. in1Na�.k a ww .,...,..y...,....,. ,.. .. _. Prepared by: (Project Manager Name and Division) Date: Acceptance of this Change Order shall constitute a modification to contract /work order identified above and will be subject to all the same terms and conditions as contained in the contract /work order indicated above, as fully as if the same were stated in this acceptance. The adjustment, if any, to the Contract shall constitute.a full and final settlement of any and all claims 01 the Contractor /Vendor / Consultant / Design Professional arising out of or related to the change set forth herein, including claims for impact and delay costs. Accepted by: Date: (Contractor /Vendor /Consultant /Design Professional and Name of Firm, if project applicable) Approved by: (Design Professional and Name of Firm, if project applicable) Approved by: (Procurement Professional Page 27 of 33 Date: Date: Multi -Contractor Award Agreement 2017.006 Ver.1 CAO ❑ this exhibit is not applicable OWNER'S Project No. PROJECT: CONTRACTOR Contract For _ Contract Date EXHIBIT G CERTIFICATE OF SUBSTANTIAL COMPLETION ENGINEER'S Project No. This Certificate of Substantial completion applies to all Work under the Contract documents or to the -following specified parts thereof: To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the contract documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all- inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to Documents. The items in the tentative list shall complete all the Work in accordance with the Contract Docu be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. Page 28 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: RESPONSIBILITIES: OWNER: CONTRACT OR: The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on By: Design Professional Type Name and Title 20 CONTRACTOR accepts this G�ertificate of Substantial Completion on 120_ By: CONTRACTOR Type Name and Title OWNER accepts this Certificate of Substantial Completion on 20_ By: OWNER Type Name and Title Page 29 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 C;ACi ❑ this exhibit is not applicable OWNER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date EXHIBIT H CERTIFICATE OF FINAL COMPLETION ENGINEER'S Project No. This Certificate of Final completion applies to all Work under the Contract documents. OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be finally complete in accordance with the contract documents on: DATE OF FINAL COMPLETION The warranty in Exhibit I is attached to and made a part of this Certificate: Page 30 of 33 Multi -Contractor Award Agreement 2017.006 Ver.1 t"AO Executed by Design Professional on Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Final Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Final Completion on 20 OWNER By: Type Name and Title Page 31 of 33 20_ Multi -Contractor Award Agreement 2017.006 Ver.1 Ct�.O ❑ this exhibit is not applicable EXHIBIT I WARRANTY In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the contract either directly performed by the CONTRACTOR or at the express request of the CONTRACTOR by a SUBCONTRACTOR or CONSULTANT. Project Name: Date of Final Completion: Name and Address of CONTRACTOR: CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of all defects of materials and workmanship for a period of one year from the DATE OF FINAL COMPLETION. The undersigned party further agrees that it will, at its own expense, replace and/or repair all defective work and materials and all other work damaged by any defective work upon written demand by the COUNTY. It is further understood that further consideration for this warranty and guaranty is the consideration given for the requirement pursuant to the general conditions and specifications under which the contract was let that such warranty and guaranty would be given. This warranty and guaranty is in addition to any other warranties or guaranties for the work performed under the contract and does not constitute a waiver of any rights provided pursuant to Florida Statutes, Chapter 95, et seq. DATE: CONTRACTOR BY: Attest: Page 32 of 33 Multi -Award Agreement 2017.006 Ver.l Description: Other Exhibit/Attachment Exhibit 1- Federal Grant Provisions following this page (pages ❑ this exhibit is not applicable thI ough 9 ) Page 33 of 33 Multi -Award Agreement 2017.006 Vecl CACi EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES FEDERAL EMERGENCY MANAGEMENT AGENCY PUBLIC ASSISTANCE This project activity is funded in whole or in part by the Federal Government, or an Agency thereof. Federal Law requires that the Applicant's contracts relating to the project include certain provisions. Per uniform requirements of federal awards (2 CFR Part 200.23) the definition of CONTRACTOR is an entity that receives a contract (including a purchase order). Compliance with Federal Law, Regulations and Executive Orders: The Sub -Recipient (County) agrees to include in the subcontract that (i) the subcontractor is bound by the terms of the Federally -Funded Subaward and Grant Agreement, (ii) the subcontractor is bound by all applicable state and Federal laws and regulations, and (iii) the subcontractor shall hold the Division and Sub -Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. Specifically, the Contractor shall be responsible for being knowledgeable and performing any and all services under this contract in accordance with the following governing regulations along with any and all other relevant Federal, State, and local laws, regulations, codes and ordinances: 0 2 C.F.R. Part 200 Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards 0 44 C.F.R. Part 206 o The Robert T. Stafford Disaster Relief and Emergency Assistance Act, Public Law 93- 288, as amended, 42 U.S.C. 5121 et seq., and Related Authorities o FEMA Public Assistance Program and Policy Guide, 2017 (in effect for incidents declared on or after April 1, 2017) Reporting: The contractor will provide any information required to comply with the grantor agency requirements and regulations pertaining to reporting. It is important that the contractor is aware of the reporting requirements of the County, as the Federal or State granting agency may require the contractor to provide certain information, documentation, and other reporting in order to satisfy reporting requirements to the granting agency. Access to Records: (1) The contractor agrees to provide the County, the FEMA Administrator, the Comptroller General of the United States, or any of their authorized representative's access to any books, documents, papers, and records of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts, and transcriptions. (2) The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. (3) The contractor agrees to provide the FEMA Administrator or his authorized representatives' access to construction or other work sites pertaining to the work being completed under the contract. DHS Seal, Logo, and Flags: The contractor shall not use the DHS seal(s), logos, crests, or reproductions of flags or likenesses of DHS agency officials without specific FEMA pre- approval. No Obligation by Federal Government: The Federal Government is not a party to this contract and is not subject to any obligations or liabilities to the non -Federal entity, contractor, or any other party pertaining to any matter resulting from the contract. Program Fraud and False or Fraudulent Statements or Related Acts: The contractor acknowledges that 31 U.S.C. Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the contractor's actions pertaining to this contract. EXHIBIT I - 1 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES Energy Efficiency Standards: The contractor agrees to comply with mandatory standards and policies relating to energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy and Conservation Act. Termination: Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be sole judge of non-performance. In the event that the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the Agreement Amount earned through the date of termination. The Contractor shall not be entitled to any other or further recovery against the County, including, but not limited to, any damages or any anticipated profit on portions of the services not performed. Rights to Inventions Made Under a Contract or Agreement: If the Federal award meets the definition of "funding agreement" under 37 CFR §401.2 (a) and the County wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that "funding agreement," the County must comply with the requirements of 37 CFR Part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by the awarding agency. Changes: See Standard Purchase Order Terms and Conditions. Procurement of Recovered Materials (6200.322) (Over $101000): (1) In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA designated items unless the product cannot be acquired (i) Competitively within a timeframe providing for compliance with the contract performance schedule; (ii) Meeting contract performance requirements; or (iii) V a reasonable price. (2) Information about this requirement is available at EPA's Comprehensive Procurement Guidelines web site, https //www epa ov/smm/comprehensive-procurement-Guideline-cpgw rrogram Suspension and Debarment: (1) This contract is a covered transaction for purposes of 2 C.F.R. pt. 180 and 2 C.F.R. pt. 3000. As such the contractor is required to verify that none of the contractor, its principals (defined at 2 C.F.R. § 180,995), or its affiliates (defined at 2 C.F.R. § 180,905) are excluded (defined at 2 C.F.R. § 180.940) or disqualified (defined at 2 C.F.R. § 180.935). (2) The contractor must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into. (3) This certification is a material representation of fact relied upon by the County. If it is later determined that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pits 3000, subpart C, in addition to remedies available to the County, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. (4) The bidder or proposer agrees to comply with the requirements of 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions. Contracting with small and minority businesses, women's business enterprises, and labor surplus area firms §200.321 (a) The Solicitor must take all necessary affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whenever possible. (b) Affirmative steps must include: (1) Placing qualified small and minority businesses and women's business enterprises on solicitation lists; (2) Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; EXHIBIT I - 2 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES (3) Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; (4) Establishing delivery schedules, where the requirement permits, which encourage participation by small and minority businesses, and women's business enterprises; (5) Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce; and (6) Requiring the prime contractor, if subcontracts are to be let, to take the affirmative steps listed in paragraphs (1) through (5) of this section. Equal Employment Opportunity Clause (§60-1.4): Except as otherwise provided under 41 C.F.R. Part 60, all contracts that meet the definition of "federally assisted construction contract' in 41 C.F.R. § 60-1.3 must include the equal opportunity clause provided under 41 C.F.R. § 60- 1.4. During the performance of this contract, the contractor agrees as follows: The contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment, or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. II. The contractor will, in all solicitations or advertisements for employees placed by or on behalf of the contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. III. The contractor will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the contractor's legal duty to furnish information. IV. The contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. V. The contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. EXHIBIT I - 3 CAO EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES VI. The contractor will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. VII. In the event of the contractor's non-compliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be canceled, terminated or suspended in whole or in part and the contractor may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. VIII. The contractor will include the provisions of paragraphs (1) through (8) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The contractor will take such action with respect to any subcontract or purchase order as may be directed by the Secretary of Labor as a means of enforcing such provisions including sanctions for noncompliance: Provided, however, that in the event the contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction, the contractor may request the United States to enter into such litigation to protect the interests of the United States. Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708) (over $100,000): Where applicable, all contracts awarded by the solicitor in excess of $100,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). (1) Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek. (2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause ible therefor shall be set forth in paragraph (1) of this section the contractor and any subcontractor respons liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1) of this section. (3) Withholding for unpaid wages and liquidated damages. The (write in the name of the Federal agency or the loan or grant recipient) shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally -assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2) of this section. EXHIBIT I - 4 CAO EXHIBIT 1 FEDERAL CONTRACT PROVISIONS AND ASSURANCES (4) Subcontracts. The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph (1) through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1) through (4) of this section." Administrative, Contractual, or Legal Remedies (over $150,000): Unless otherwise provided in this contract, all claims, counter -claims, disputes and other matters in question between the local government and the contractor, arising out of or relating to this contract, or the breach of it, will be decided by arbitration, if the parties mutually agree, or in a Florida court of competent jurisdiction. Clean Air Act and Federal Water Pollution Control Act: (over $150,000) (1) The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. § 7401 et seq. (2) The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq. (3) The contractor agrees to report each violation to the County and understands and agrees that the County will, in turn, report each violation as required to assure notification to the Federal Emergency Management Agency, and the appropriate Environmental Protection Agency Regional Office. (4) The contractor agrees to include these requirements in each subcontract exceeding $150,000 financed in whole or in part with Federal assistance provided by FEMA. Byrd Anti -Lobbying Amendment (31 U.S.C. § 1352 (as amended) (over $100,000): Contractors who apply or bid for an award of $100,000 or more shall file the required certification. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant, or any other award covered by 31 U.S.C. § 1352. Each tier shall also disclose any lobbying with non -Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the recipient." State Provisions Convicted Vendor and Discriminatory Vendors List Those who have been placed on the convicted vendor list following a conviction for a public entity crime or on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with a public entity, and may not transact business with any public entity in excess of $25,000.00 for a period of 36 months from the date of being placed on the convicted vendor list or on the discriminatory vendor list. Lobbying: No funds received pursuant to this Agreement may be expended for lobbying the Legislature, the judicial branch or any state agency. Inspector General Cooperation: The Parties agree to comply with Section 20.055(5), Florida Statutes, for the inspector general to have access to any records, data and other information deemed necessary to carry out his or her duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5), Florida Statutes. Record Retention - The contractor shall maintain and retain sufficient records demonstrating its compliance with the terms of the Agreement for a period of at least five (5) years after final payment is made and shall allow the County, FDEM, or its designee's access to such records upon request. EXHIBIT I - 5 EXHIBIT I ccntoni PnKlTr?Ar T PRnViCInMA ANn ASSURANCES Acknowledgement of Terms, Conditions, and Grant Clauses Certification If the vendor subcontracts any of the work required under this Agreement, a copy of the signed subcontract must be available to the Department for review and approval. The vendor agrees to include in the subcontract that (1) the subcontractor is bound by the terms of this Agreement, (ii) the subcontractor is bound by all applicable state and federal laws and regulations, and (ii) the subcontractor shall hold the Department and Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. The recipient shall document in the quarterly report the subcontractor's progress in performing its work under this agreement. For each subcontract, the Recipient shall provide a written statement to the Department as to whether the subcontractor is a minority vendor as defined in Section 288,703, Fla. $tat. Qn behalf of my firm, I acknowledge, the grant requirements identified in this document. Vendor(Contractor Name EBL Partners LLC /Paul Benson Date 2J14/2t119 Authorized Signature EXHIBIT I - 6 CAO EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY and VOLUNTARY EXCLUSION Contractor Covered Transactions (1) The prospective subcontractor of the Sub -recipient, Collier County, certifies, by submission of this document, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency. (2) Where the Sub -recipient's subcontractor is contract. shall attach an explanation to this form. CONTRACTOR By: Signature Name and 1482 Rail Head Blvd Street Address Na les FI, 34110 City, State, Zip 043402330 DUNS Number 1 MI 2/14/2Q14 Date unable to certify to the above statement, the prospective Sub -Recipient Name: Collier County Board of County Commissioners DEM Contract Number: Z0001 FEMA Project Number: 4337DRFLP0000001 EXHIBIT I - 7 CAU f~xxiL��r � FEDERAL CONTRACT PROVISIONS AND ASSURANCES kttiA tm uar tsd tr sWe sin v 311; F2uire thct t)Mhr: to 61W Viw*Vd* ct pravtt, sol'm e€mc antazvatt tfalt vaIkjaer a t�tilhfCzdtt� THIPth�'P"T�3J4di�+frSEB2 � r.:Jr{essn�iuu xrxa;i��vr.� ..� — S Mpsl3aiC 6=ELCleil[?7t CC€t7T�fU D!S €7tiAt{FAFEFi, ;E.RE?J�! Y �N ctSTfrtEACTIVi'tV UP' IMSCi2,°81't3B�°;5'_. ftNoTi'ioRWO�i F16t1£SdEiSF{f€Lpff13E2 /YfiE? v fdS €ti7C7bz,l7 �I' &f barfaAa�aon OR lm�j iSF�ntl UiS4CtVAMigUFi) ��rrr U;tfti55l3ACf?F�Fidl2iNStiik(Sa$ttAE44Ctt8RSIPES3 TABU S S25Utl'A15aN7 Y id FdtS'v T2kY3DAF 1<3Eit.r£C'fiiit„Y,I cf94`E7'E isl? UW$c? Y Oplan'f Y N €STt55ifiil',Sdtl#vi3RL'J,51tT: S' 83 T�'.* 13`tiiSSliHi33�.iAP�R F`�,- ,',.r�=c-� 4 T. €F 3i€ i iff S S; €P`t2 Tii Cie 3$ t3R E4 s d fEi€1 s#t t3 tk d �I,�f C GE€D 3 € Y, �dxd P �3L a' E�. SMAU t3t#5 € 5CE3i €tf�,£ SERVICE MAIMED VEY1:E AWo €li€€'2 Is ot ' TE TSB NEXT SEC`f ON "mimmArim on MMIM-? j Tim CbF "Em Cain e5waGarix:£Wx f7 WE'%`>m"y Dr C` &B"t=7 : : I 4YYiAtY, all BE complETED BY PRIM Eftb6l'tKUNTRACTOR OAig MAIL ali")Uit%?;S G K40.E (5urfg.PTIY ) 'CFl"st%i dE $Uiz��t �2� T�1 IY OIL "ttes a7fa iaafiaa is t ff sn €risk i reis x. amlap UBE � f St?E ptstl ip�tia s in f�rtzrallyfur� si ;nntt�{s, it3Y am �=Rr d is€ E cr Ft tit: atT�a tc �sglttt�Y�ry ntsJ x,if i� i�nrtia �„rt r�.th� tY.�ttF<ctcml Y�nxs. Iris its,'m ml;-,:t tag �:arritii�� Yim� t f t'�igc 90 e udic4xatsan kf 79nd xvhvtt W=rAZOn—A a ewunty mrArwc thAr T.uime wlPm eovd m up dm: thasrrtnrmation for tile gram VOMPU�Mce ties. isT'stcA,racrisan 4fiA _. Strb Dni. Asian Am2rlmn Sall — R i s it APA @dray-B anQri3Y 4 OMI) �dFiVJ c3,: ru cf riaerX ymri i5iy7E EXHIBIT I - 8 CAO EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES LOBBYING CERTIFICATION (To be submitted with each bid or offer exceeding $100.000) The undersigned [Contractor] certifies, to the best of his or her knowledge, that; 1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. 2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form- LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions. 3. The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including subcontracts, subgrants, and contracts under grants, loans, and cooperative agreements) and that all subrecipients shall certify and disclose accordingly. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this fails totion imposed by 31, U.S.C. § 1352 (as amended by the Lobbying Disclosure Act of 1995). Any person tfile he required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The Contractor certifies or affirms the truthfulness and accuracy of each statement of its certification and disclosure, if any. In addition, the Contractor understands and agrees that the provisions,of 31 U.S.C. § 3801 et seq., apply to this certification and disclosure, if any. Contractor (Firm Name) Signature of Contractor's Authorize and Title of 2/14/2Q19 Date EXHIBIT I - 9 o CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) 5/22/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: if the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER NAME: Brown & Brown Of Florida, Inc. PHONE FAX 1421 Pine Ridge Road E-MAIL • 239-262-5143 A/c No): 239-261-8265 Suite 200 ADDRESS: _certs@bbnapies.com Naples FL 34109 INSURERS AFFORDING COVERAGE NAIC# INSURER A: FCCI Commercial Insurance Company 33472 INSURED EBLPA-1 INSURER B : FCCI Insurance Company 10178 EBL Partners , LLC INSURER C : Allied World Surplus Lines Insurance Company 24319 1482 Rail Head Blvd Naples FL 34110 INSURER D : Travelers Casualty Insurance Company of America 19046 INSURER E : rnv�onncc f CATICI!`ATF tJ1IMRFR•7R'29(14Rd1 RFVISIt7N NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES, LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, INSR LTR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF MMIDDYYY /Y POLICY EXP MMIDD/YYYY LIMITS A X COMMERCIAL GENERAL LIABILITY Y Y CPP0018652 5/28/2019 5/28/2020 EACH OCCURRENCE $1,000,000 CLAIMS -MADE FI OCCUR DAMAGE TO RENTED PREMISES Ea occurrence $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG $2,000,000 POLICY jE� LOC OTHER: I $ A AUTOMOBILE LIABILITY Y Y CA10001419201 5/28/2019 5/28/2020 COMBINED SINGLE LIMIT (Ea accident $ 1,000,000 X ANY AUTO BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ OWNED SCHEDULED AUTOS ONLY AUTOS HIRED NON -OWNED AUTOS ONLY AUTOS ONLY PROPERTY DAMAGE Per accident $ D X UMBRELLALIAB OCCUR Y ZUP31M8024019NF 5/28/2019 5/28/2020 EACH OCCURRENCE $3,000,000 EXCESS LIAB CLAIMS -MADE AGGREGATE $ 3,000,000 DED X RETENTION $ 1n nno $ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN ANYPROPRIETOR/PARTNER/EXECUTIVE ❑ OFFICER/MEMBEREXCLUDED? (Mandatory in NH) N/A Y 001 WC19A72343 5/25/2019 5/25/2020 X PER STATUTE OTH- ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ 1,000,000 C Professional Liability 03090947 7/2/2019 7/2/2020 Per Claim Aggregate Retention $1,0001000 110003000 10,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) General Contractor / Consultant Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County is included as an additional insured under the captioned General Liability and Automobile policies when required by written contract, for all and any work performed on behalf of Collier County. General Liability includes Blanket Additional Insured - Your Work as required in written contract per form CGL 084 (10/13); Primary and Non -Contributory Coverage per form CGL 025 (11/08); Blanket Waiver of Transfer or Rights of Recovery & Per Project Aggregate Limit per form CGL088 (10/13) Workers Compensation includes Blanket Waiver of Subrogation per form #WC000313 - Waiver of Our Right to Recover from Others. General Liability, Automobile Liability and Workers Compensation policies are included in the Umbrella Underlying Schedule. Umbrella Liability is follow form. TE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Collier County Board of County Commissiners 3295 Tamiami Trail East AUTHORI2EDREPRESENTATIVE Naples FL 34112 Pi Q/W1+ .fo 't*Q� ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY Insured Name: EBL PARTNERS LLC Policy Number: 001-W18A�72343 Agency Name: 283, Brown & Brown of FL Inc/Naples WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us. This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. SCHEDULE All persons or organizations that, in a written contract executed by bath parties prior to the date of the injury covered by this policy, require you to obtain this agreement from us. This endorsement changes the policy to which it is attached and Is effective on the date issued unless otherwise noted. Issued by: FCCz Insurance company 24570 Endorsement Number: 0000012 Effective Date: 5/25/18 Date Issued: 5/25/18 Countersigned by Authorized Representative WC 00 03 13 Copyright 1983 National Council on Compensation Insurance EZ0201, 6104 COMMERCIAL GENERAL LIABILITY CGL 025 (11 08) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSUREDS - PRIMARY/NON-CONTRIBUTORY COVERAGE WHEN REQUIRED BY CONTRACT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM The following is added to SECTION IV —Commercial General Liability Conditions, Paragraph 4, entitled "Other Insurance", subsection b. entitled "Excess Insurance", paragraph (1): This insurance is excess over: (v) Any other insurance naming an additional insured as an insured on a primary basis, excess, contingent or on any other basis unless a written contract specifically requires that this insurance be primary and noncontributing. The written contract must be currently in effect or become effective during the term of this policy and must be executed prior to the "bodily injury", "property damage" or "personal and advertising injury." CGL 025 (11 08) Includes copyrighted material of Insurance Services Office, with its permission. Page 1 of 1 Copyright 2008 FCCI Insurance Group. COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. FIRST CHOICE CONTRACTORS LIABILITY ENDORSEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM NOTE: The following are additions, replacements and amendments to the Commercial General Liability Coverage Form, and will apply unless excluded by separate endorsement(s) to the Commercial General Liability Coverage Form. The COMMERCIAL GENERAL LIABILITY COVERAGE FORM is amended as follows: SECTION I -COVERAGES, COVERAGE A. BODILY INJURY AND PROPERTY DAMAGE is amended as follows: 1. Extended "Property Damage" Exclusion 2.a., Expected or Intended Injury, is replaced with the following: a. "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. 2. Non -owned Watercraft Exclusion 2.g. (2) (a) is replaced with the following: (a) Less than 51 feet long; and 3. Property Damage Liability —Borrowed Equipment The following is added to Exclusion 2.j. (4): Paragraph (4) of this exclusion does not apply to "property damage" to borrowed equipment while at a jobsite and not being used to perform operations. The most we will pay for "property damage" to any one borrowed equipment item under this coverage is $25,000 per "occurrence". The insurance afforded under this provision is excess over any other valid and collectible property insurance (including deductible) available to the insured, whether primary, excess, contingent or on any other basis. 4. Limited Electronic Data Liability Exclusion 2.p. is replaced with the following: p. Electronic Data Damages arising out of the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate "electronic data" that does not result from physical injury to tangible property. The most we will pay under Coverage A for "property damage" because of all loss of "electronic data" arising out of any one "occurrence" is $10,000. CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 1 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) We have no duty to investigate or defend claims or "suits" covered by this Limited Electronic Data Liability coverage. The following definon is added to SECTION V —DEFINITIONS of the Coverage Form: "Electronic data" means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software (including systems and applications software), hard or floppy disks, CD- ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. For purposes of this Limited Electronic Data Liability coverage, the definition of "Property Damage" in SECTION V — DEFINITIONS of the Coverage Form is replaced by the following: 17. "Property damage" means: a. Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use shall be deemed to occur at the time of the physical injury that caused it; b. Loss of use of tangible property that is not physically injured. All such loss of use shall be deemed to occur at the time of the "occurrence" that caused it; c. Loss of, loss of use of, damage to, corruption of, inability to access, or inability to properly manipulate "electronic data", resulting from physical injury to tangible property. All such loss of "electronic data" shall be deemed to occur at the time of the "occurrence" that caused it. For purposes of this insurance, "electronic data" is not tangible property. SECTION I —COVERAGES, COVERAGE B. PERSONAL AND ADVERTISING INJURY LIABILITY is amended as follows: Paragraph 2.e. Exclusions —the Contractual Liability Exclusion is deleted. SECTION I —COVERAGES, the following coverages are added: COVERAGE D. VOLUNTARY PROPERTY DAMAGE 1. Insuring Agreement We will pay, at your request, for "property damage" caused by an "occurrence", to property of others caused by you, or while in your possession, arising out of your business operations. The amount we will pay for damages is described in SECTION III LIMITS OF INSURANCE. 2. Exclusions This insurance does not apply to: "Property Damage" to: a. Property at premises owned, rented, leased or occupied by you; b. Property while in transit; c. Property owned by, rented to, leased to, loaned to, borrowed by, or used by you; CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 2 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) d. Premises you sell, give away, or abandon, if the "property damage" arises out of any part of those premises; e. Property caused by or arising out of the "products -completed operations hazard"; f. Motor vehicles; g. "Your product" arising out of it or any part of it; or h. "Your work" arising out of it or any part of it. 3. Deductible We will not pay for loss in any one "occurrence" until the amount of loss exceeds $250. We will then pay the amount of loss in excess of $250 up to the applicable limit of insurance. 4. Cost Factor In the event of a covered loss, you shall, if requested by us, replace the damaged property or furnish the labor and materials necessary for repairs thereto at your actual cost, excluding profit or overhead charges. The insurance afforded under COVERAGE D is excess over any other valid and collectible property or inland marine insurance (including the deductible applicable to the property or inland marine coverage) available to you whether primary, excess, contingent or any other basis. Coverage D covers unintentional damage or destruction, but does not cover disappearance, theft, or loss of use. The insurance under COVERAGE D does not apply if a loss is paid under COVERAGE E. COVERAGE E. CARE, CUSTODY OR CONTROL 1. Insuring Agreement We will pay those sums that the insured becomes legally obligated to pay as damages because of "property damage" caused by an "occurrence", to property of others while in your care, custody, or control or property of others as to which you are exercising physical control if the "property damage" arises out of your business operations. The amount we will pay for damages is described in SECTION III LIMITS OF INSURANCE. 2. Exclusions This insurance does not apply to: "Property Damage" to: a. Property at premises owned, rented, leased or occupied by you; b. Property while in transit; c. Premises you sell, give away, or abandon, if the "property damage" arises out of any part of those premises; d. Property caused by or arising out of the "products -completed operations hazard"; CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 3 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) e. Motor vehicles; f. "Your product" arising out of it or any part of it; or g. "Your work" arising out of it or any part of it. 3. Deductible We will not pay for loss in any one "occurrence" until the amount of loss exceeds $250. We will then pay the amount of loss in excess of $250 up to the applicable limit of insurance. 4. Cost Factor In the event of a covered loss, you shall, if requested by us, replace the damaged property or furnish the labor and materials necessary for repairs thereto at your actual cost, excluding profit or overhead charges. The insurance afforded under COVERAGE E is excess over any other valid and collectible property or inland marine insurance (including the deductible applicable to the property or inland marine coverage) available to you whether primary, excess, contingent or any other basis. The insurance under COVERAGE E does not apply if a loss is paid under COVERAGE D. COVERAGE F. LIMITED PRODUCT WITHDRAWAL EXPENSE 1. Insuring Agreement a. If you area "seller", we will reimburse you for "product withdrawal expenses" associated with "your product" incurred because of a "product withdrawal" to which this insurance applies. The amount of such reimbursement is limited as described in SECTION III -LIMITS OF INSURANCE. No other obligation or liability to pay sums or perform acts or services is covered. a. This insurance applies to a "product withdrawal" only if the "product withdrawal" is initiated in the "coverage territory" during the policy period because: (1) You determine that the "product withdrawal" is necessary; or (2) An authorized government entity has ordered you to conduct a "product withdrawal". c. We will reimburse only those "product withdrawal expenses" which are incurred and reported to us within one year of the date the "product withdrawal" was initiated. d. The initiation of a "product withdrawal" will be deemed to have been made only at the earliest of the following times: (1) When you have announced, in any manner, to the general public, your vendors or to your employees (other than those employees directly involved in making the determination) your decision to conduct a "product withdrawal" This applies regardless of whether the determination to conduct a "product withdrawal" is made by you or is requested by a third party; (2) When you received, either orally or in writing, notification of an order from an authorized government entity to conduct a "product withdrawal; or CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 4 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) (3) When a third party has initiated a "product withdrawal" and you communicate agreement with the "product withdrawal", or you announce to the general public, your vendors or to your employees (other than those employees directly involved in making the determination) your decision to participate in the "product withdrawal", whichever comes first. e. "Product withdrawal expenses" incurred to withdraw "your products" which contain: (1) The same "defect" will be deemed to have arisen out of the same "product withdrawal' ; or (2) A different "defect" will be deemed to have arisen out of a separate "product withdrawal" if newly determined or ordered in accordance with paragraph 1.b of this coverage. 2. Exclusions This insurance does not apply to "product withdrawal" expenses" arising out of: a. Any "product withdrawal" initiated due to: (1) The failure of "your products" to accomplish their intended purpose, including any breach of warranty of fitness, whether written or implied. This exclusion does not apply if such failure has caused or is reasonably expected to cause "bodily injury" or physical damage to tangible property. (2) Copyright, patent, trade secret or trademark infringements; (3) Transformation of a chemical nature, deterioration or decomposition of "your product", except if it is caused by: (a) An error in manufacturing, design, processing or transportation of "your product"; or (b) "Product tampering". (4) Expiration of the designated shelf life of "your product". b. A "product withdrawal", initiated because of a "defect" in "your product" known to exist by the Named Insured or the Named Insured's "executive officers", prior to the inception date of this Coverage Part or prior to the time "your product" leaves your control or possession. c. Recall of any specific products for which "bodily injury" or "property damage" is excluded under Coverage A - Bodily Injury And Property Damage Liability by endorsement. d. Recall of "your products" which have been banned from the market by an authorized government entity prior to the policy period. e. The defense of a claim or "suit" against you for "product withdrawal expenses". 3. For the purposes of the insurance afforded under COVERAGE F, the following is added to 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit Condition under SECTION IV —COMMERCIAL GENERAL LIABILITY CONDITIONS: e. Duties In The Event Of A "Defect" Or A "Product Withdrawal" (1) You must see to it that we are notified as soon as practicable of any actual, suspected or threatened "defect" in "your products", or any governmental investigation, that may result in a "product withdrawal". To the extent possible, notice should include: CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 5 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) (a) How, when and where the "defect" was discovered; (b) The names and addresses of any injured persons and witnesses; and (c) The nature, location and circumstances of any ry or damage arising out of use or consumption of "your product". (2) If a "product withdrawal" is initiated, you must: (a) Immediately record the specifics of the "product withdrawal" and the date it was initiated; (b) Send us written notice of the "product withdrawal" as soon as practicable; and (c) Not release, consign, ship or distribute by any other method, any product, or like or similar products, with an actual, suspected or threatened defect. (3) You and any other involved insured must: (a) Immediately send us copies of pertinent correspondence received in connection with the "product withdrawal"; (b) Authorize us to obtain records and other information; and (c) Cooperate with us in our investigation of the "product withdrawal". 4. For the purposes of this Coverage F, the following definitions are added to the Definitions Section: a. "Defect" means a defect, deficiency or inadequacy that creates a dangerous condition. b. "Product tampering" is an act of intentional alteration of "your product" which may cause or has caused "bodily injury" or physical injury to tangible property. When "product tampering" is known, suspected or threatened, a "product withdrawal" will not be limited to those batches of "your product" which are known or suspected to have been tampered with. c. "Product withdrawal" means the recall or withdrawal of "your products", or products which contain "your products", from the market or from use, by any other person or organization, because of a known or suspected "defect" in "your product", or a known or suspected "product tampering", which has caused or is reasonably expected to cause "bodily injury" or physical injury to tangible property. d. "Product withdrawal expenses" means those reasonable and necessary extra expenses, listed below paid and directly related to a "product withdrawal": (1) Costs of notification; (2) Costs of stationery, envelopes, production of announcements and postage or facsimiles; (3) Costs of overtime paid to your regular non -salaried employees and costs incurred by your employees, including costs of transportation and accommodations; (4) Costs of computer time; (5) Costs of hiring independent contractors and other temporary employees; (6) Costs of transportation, shipping or packaging; CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 6 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) (7) Costs of warehouse or storage space; or (8) Costs of proper disposal of your products", or products that contain "your products", that cannot be reused, not exceeding your purchase price or your cost to produce the products; but "product withdrawal expenses" does not include costs of the replacement, repair or redesign of "your product", or the costs of regaining your market share, goodwill, revenue or profit. e. "Seller" means a person or organization that manufactures, sells or distributes goods or products. "Seller" does not include a "contractor" as defined elsewhere in this endorsement. The insurance under COVERAGE F does not apply if a loss is paid under COVERAGE G. COVERAGE G. CONTRACTORS ERRORS AND OMISSIONS 1. Insuring Agreement If you area "contractor", we will pay those sums that you become legally obligated to pay as damages because of "property damage" to "your product", "your work" or "impaired property", due to faulty workmanship, material or design, or products including consequential loss, to which this insurance applies. The damages must have resulted from your negligent act, error or omission while acting in your business capacity as a contractor or subcontractor or from a defect in material or a product sold or installed by you while acting in this capacity. The amount we will pay for damages is described in SECTION III LIMITS OF INSURANCE. We have no duty to investigate or defend claims or "suits" covered by this Contractors Errors or Omissions coverage. This coverage applies only if the "property damage" occurs in the "coverage territory' during the policy period. This coverage does not apply to additional insureds, if any. Supplementary Payments — Coverage A and B do not apply to Coverage G, Contractors Errors and Omissions. 2. Exclusions This insurance does not apply to: a. "Bodily injury" or "personal and advertising injury". b. Liability or penalties arising from a delay or failure to complete a contract or project, or to complete a contract or project on time. c. Liability because of an error or omission: (1) In the preparation of estimates or job costs; (2) Where cost estimates are exceeded; (3) In the preparation of estimates of profit or return on capital; (4) In advising or failure to advise on financing of the work or project; or (5) In advising or failing to advise on any legal work, title checks, form of insurance or suretyship. CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 7 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) d. Any liability which arises out of any actual or alleged infringement of copyright or trademark or trade dress or patent, unfair competition or piracy, or theft or wrongful taking of concepts or intellectual property. e. Any liability for damages: (1) From the intentional dishonest, fraudulent, malicious or criminal acts of the Named Insured, or by any partner, member of a limited liability company, or executive officer, or at the direction of any of them; or (2) Which is in fact expected or intended by the insured, even if the injury or damage is of a different degree or type than actually expected or intended. f. Any liability arising out of manufacturer's warranties or guarantees whether express or implied. g. Any liability arising from "property damage" to property owned by, rented or leased to the insured. h. Any liability incurred or "property damage" which occurs, in whole or in part, before you have completed "your work." "Your work" will be deemed completed at the earliest of the following times: (1) When all of the work called for in your contract or work order has been completed; (2) When all the work to be done at the job site has been completed if your contract calls for work at more than one job site; or (3) When that part of the work done at a job site has been put to its intended use by any person or organization other than another contractor or subcontractor working on the same project. Work that may need service or maintenance, correction, repair or replacement, but which is otherwise complete, will be treated as complete. Any liability arising from "property damage" to products that are still in your physical possession. j. Any liability arising out of the rendering of or failure to render any professional services by you or on I our behalf, but only with respect to either or both of the following operations: (1) Providing engineering, architectural or surveying services to others; and (2) Providing or hiring independent professionals to provide engineering, architectural or surveying services in connection with construction work you perform. Professional services include the preparing, approving or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders, or drawings and specifications. Professional services also include supervisory or inspection activities performed as part of any related architectural or engineering activities. But, professional services do not include services within construction means, methods, techniques, sequences and procedures employed by you in connection with construction work you perform. k. Your loss of profit or expected profit and any liability arising therefrom. "Property damage" to property other than your product," "your work" or "impaired property." m. Any liability arising from claims or "suits" where the right of action against the insured has been relinquished or waived. CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 8 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) n. Any liability for "property damage" to your work" if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor. o. Any liability arising from the substitution of a material or product for one specified on blueprints, work orders, contracts or engineering specifications unless there has been written authorization, or unless the blueprints, work orders, contracts or engineering specifications were written by you, and you have authorized the changes. p. Liability of others assumed by the insured under any contract or agreement, whether oral or in writing. This exclusion does not apply to liability for damages that the insured would have in the absence of the contract or agreement. 3. For the purposes of Coverage G, the following definition is added to the Definitions section: a. "Contractor" means a person or organization engaged in activities of building, clearing, filing, excavating or improvement in the size, use or appearance of any structure or land. "Contractor" does not include a "seller' as defined elsewhere in this endorsement. 4. Deductible We will not pay for loss in any one "occurrence" until the amount of loss exceeds $250. The limits of insurance will not be reduced by the application of the deductible amount. We may pay any part or all of the deductible amount to effect settlement of any claim or "suit", and upon notification of the action taken, you shall promptly reimburse us for such part of the deductible amount as has been paid by us. 5. Cost Factor In the event of a covered loss, you shall, if requested by us, replace the damaged property or furnish the labor and materials necessary for repairs thereto at your actual cost, excluding profit or overhead charges. The insurance under COVERAGE G does not apply if a loss is paid under COVERAGE F. EXPANDED COVERAGE FOR TENANT'S PROPERTY AND PREMISES RENTED TO YOU The first paragraph after subparagraph (6) in Exclusion j., Damage to Property is amended to read as follows: Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire) to premises, including the contents of such premises, rented to you. A separate limit of insurance applies to Damage To Premises Rented To You as described in Section III — Limits Of Insurance. SECTION I -COVERAGES, SUPPLEMENTARY PAYMENTS — COVERAGE A and B is amended as follows: All references to SUPPLEMENTARY PAYMENTS — COVERAGES A and B are amended to SUPPLEMENTARY PAYMENTS —COVERAGES A, B, D, E, and G. 1. Cost of Bail Bonds Paragraph 1.b. is replaced with the following: b. Up to $2,500 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 9 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) 2. Loss of Earnings Paragraph 1a is replaced with the following: d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. SECTION II —WHO IS AN INSURED is amended as follows: 1. Incidental Malpractice Paragraph 2.a.(1)(d) is replaced with the following: (d) Arising out of his or her providing or failing to provide professional health care services. However, this exclusion does not apply to a nurse, emergency medical technician or paramedic employed by you to provide medical services, unless: (i) You are engaged in the occupation or business of providing or offering medical, surgical, dental, x-ray or nursing services, treatment, advice or instruction; or (ii) The "employee" has another insurance that would also cover claims arising under this provision, whether the other insurance is primary, excess, contingent or on any other basis. 2. Broadened Who Is An Insured The following are added to Paragraph 2.: Subsidiaries e. Your subsidiaries if: (1) They are legally incorporated entities; and (2) You own more than 50% of the voting stock in such subsidiaries as of the effective date of this policy. If such subsidiaries are not shown in the Declarations, you must report them to us within 180 days of the inception of your original policy. Additional Insureds f. Any person or organization described in paragraphs g. through k. below whom you are required to add as an additional insured on this policy under a written contract or agreement in effect during the term of this policy, provided the written contract or agreement was executed prior to the "bodily injury", "property damage" or "personal and advertising injury" for which the additional insured seeks coverage. However, the insurance afforded to such additional insured(s): (1) Only applies to the extent permitted by law; (2) Will not be broader than that which you are required by the contract or agreement to provide for such additional insured; (3) Will not be broader than that which is afforded to you under this policy; (4) Is subject to the conons described in paragraphs g2 through k. below; and CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 10 of 16 Copyright 9013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) (5) Nothing herein shall extend the term of this policy. g. Owner, Lessor or Manager of Premises If the additional insured is an owner, lessor or manager of premises, such person or organization shall be covered only with respect to liability arising out of the ownership, maintenance or use of that part of any premises leased to you and subject to the following additional exclusions: (1) Any "occurrence" that takes place after you cease to occupy those premises; or (2) Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. h. State or Governmental Agency or Subdivision or Political Subdivision —Permits or Authorizations If the additional insured is the state or any political subdivision, the state or political subdivision shall be covered only with respect to operations performed by you or on your behalf for which the state or political subdivision has issued a permit or authorization. This insurance does not apply to: (1) "Bodily injury", "property damage", or "personal and advertising injury" arising out of operations performed for the federal government, state or municipality; or (2) "Bodily injury" or "property damage" included within the "products -completed operations hazard". i. Lessor of Leased Equipment If the additional insured is a lessor of leased equipment, such lessor shall be covered only with respect to liability for "bodily injury", "property damage" a "personal and advertising injury' caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person(s) or organization(s). With respect to the insurance afforded to these additional insureds, this insurance does not apply to any "occurrence" which takes place after the equipment lease expires. j. Mortgagee, Assignee, or Receiver If the additional Insured is a mortgagee, assignee, or receiver of premises, such mortgagee, assignee or receiver of premises is an additional insured only with respect to their liability as mortgagee, assignee, or receiver and arising out of the ownership, maintenance, or use of the premises by you. This insurance does not apply to structural alterations, new construction and demolition operations performed by or for that person or organization. k. Vendor If the additional insured is a vendor, such vendor is an additional insured only with respect to "bodily injury" or "property damage" caused by "your products" which are distributed or sold in the regular course of the vendor's business, subject to the following additional exclusions: (1) The insurance afforded to the vendor does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in absence of the contract or agreement. (b) Any express warranty unauthorized by you; CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 11 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) (c) Any physical or chemical change in your product" made intentionally by the vendor; (d) Repackaging, unless unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container; (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: The exceptions contained in Subparagraphs d. or f.; or ii. Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization, from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. 3. Newly Formed or Acquired Organizations Paragraph 3. is amended as follows: a. Coverage under this provision is afforded until the end of the policy period. d. Coverage A does not apply to product recall expense arising out of any withdrawal or recall that occurred before you acquired or formed the organization. SECTION III —LIMITS OF INSURANCE is amended as follows: 1. Paragraph 2, is replaced with the following: 2. The General Aggregate Limit is the most we will pay for the sum of: a. Medical expenses under Coverage C; b. Damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products -completed operations hazard"; c. Damages under Coverage B; d. Voluntary "property damage" payments under Coverage D; and e. Care, Custody or Control damages under Coverage E. CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 12 of 16 Copyright 2013 FCCI Insurance Group 2. 5. COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) Paragraph 5. is replaced with the following: 5. Subject to Paragraph 2. or 3. above, whichever applies, the Each Occurrence Limit is the most we will pay for the sum of: a. Damages under Coverage A; b. Medical expenses under Coverage C; c. Voluntary "property damage" payments under Coverage D; d. Care, Custody or Control damages under Coverage E; e. Limited Product Withdrawal Expense under Coverage F; and f. Contractors Errors and Omissions under Coverage G. because of all "bodily injury" and "property damage" arising out of any one "occurrence". Paragraph 6. is replaced with the following: 6. Subject to Paragraph 5. above the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of "property damage" to any one premises, while rented to you, or in the case of damage by fire or explosion, while rented to you or temporarily occupied by you with permission of the owner. The Damage to Premises Rented to You Limit is the higher of the Each Occurrence Limit shown in the Declarations or the amount shown in the Declarations as Damage To Premises Rented To You Limit. Paragraph 7. is replaced with the following: 7. Subject to Paragraph 5. above, the higher of $10,000 or the Medical Expense Limit shown in the Declarations is the most we will pay under Coverage C for all medical expenses because of "bodily injury" sustained by any one person. Paragraph 8. is added as follows: 8. Subject to Paragraph 5. above, the most we will pay under Coverage D. Voluntary Property Damage for loss arising out of any one "occurrence" is $1,500. The most we will pay in any one -policy period, regardless of the number of claims made or suits brought, is $3,000. Paragraph 9. is added as follows: 9. Subject to Paragraph 5. above, the most we will pay under Coverage E. Care, Custody or Control for "property damage" arising out of any one "occurrence" is $1,000. The most we will pay in any one -policy period, regardless of the number of claims made or suits brought, is $5,000. Paragraph 10. is added as follows: 10. Subject to Paragraph 5. above, the most we will pay under Coverage F. Limited Product Withdrawal Expense for "product withdrawal expenses" in any one -policy period, regardless of the number of insureds, "product withdrawals" initiated or number of your products" withdrawn is $10,000a CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 13 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) 8. Paragraph 11. is added as follows: 11. Subject to Paragraph 5. above, the most we will pay under Coverage G. Contractors Errors and Omissions for damage in any one -policy period, regardless of the number of insureds, claims or "suits" brought, or persons or organizations making claim or bringing "suits" is $10,000. For errors in contract or job specifications or in recommendations of products or materials to be used, this policy will not pay for additional costs of products and materials to be used that would not have been incurred had the correct recommendations or specifications been made. 9. Paragraph 12. is added as follows: 12. The General Aggregate Limit applies separately to: a. Each of your projects away from premises owned by or rented to you; or b. Each "location" owned by or rented to you. "Location" as used in this paragraph means premises involving the same or connecting lots, or premises whose connection is interrupted only by a street, roadway, waterway or right-of-way of a railroad. 10. Paragraph 13. is added as follows: 13. With respect to the insurance afforded to any additional insured provided coverage under this endorsement: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: a. Required by the contract or agreement; or b. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. SECTION IV —COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: 1. Subparagraph 2.a. of Duties In The Event Of Occurrence, Offense, Claim, or Suit is replaced with the following: a. You must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. This requirement applies only when the "occurrence" or offense is known to the following: (1) An individual who is the sole owner; (2) A partner, if you are a partnership or joint venture; (3) An "executive officer" or insurance manager, if you are a corporation; (4) A manager, if you are a limited liability company; CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 14 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) (5) A person or organization having proper temporary custody of your property if you die; (6) The legal representative of you if you die; or (7) A person (other than an "employee") a an organization while acting as your real estate manager. To the extent possible, notice should include: (1) How, when and where the "occurrence" or offense took place; (2) The names and addresses of any injured persons and witnesses; and (3) The nature and location of any injury or damage arising out of the "occurrence" or offense. 2. The following is added to Subparagraph 2.b. of Duties In The Event Of Occurrence, Offense, Claim, or Suit: The requirement in 2.b.applies only when the "occurrence" or offense is known to the following: (1) An individual who is the sole owner; (2) A partner or insurance manager, if you are a partnership or joint venture; (3) An "executive officer" or insurance manager, if you are a corporation; (4) A manager or insurance manager, if you are a limited liability company; (5) Your officials, trustees, board members or insurance manager, if you are snot -for -profit organization; (6) A person or organization having proper temporary custody of your property if you die; (7) The legal representative of you if you die; or (8) A person (other than an "employee") or an organization while acting as your real estate manager. 3. The following is added to paragraph 2. of Duties in the Event of Occurrence, Offense, Claim or Suit: e. If you report an "occurrence" to your workers compensation carrier that develops into a liability claim for which coverage is provided by the Coverage Form, failure to report such an "occurrence" to us at the time of the "occurrence" shall not be deemed a violation of paragraphs a., b., and c. above. However, you shall give written notice of this "occurrence" to us as soon as you become aware that this "occurrence" may be a liability claim rather than a workers compensation claim. 4. Paragraph 6. is replaced with the following: 6. Representations By accepting this policy, you agree: a. The statements in the Declarations are accurate and complete; b. Those statements are based upon representations you made to us; and c. We have issued this policy in reliance upon your representations. CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 15 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 088 (10 13) Any error or omission in the description of, or failure to completely describe or disclose any premises, operations or products intended to be covered by the Coverage Form will not invalidate or affect coverage for those premises, operations or products, provided such error or omission or failure to completely describe or disclose premises, operations or products was not intentional. You must report such error or omission to us as soon as practicable after its discovery. However, this provision does not affect our right to collect additional premium charges or exercise our right of cancellation or nonrenewal. 5. The following is added to paragraph 8. Transfer Of Rights Of Recovery Against Others To Us: However, we waive any right of recovery we may have because of payments we make for injury or damage arising out of your ongoing operations or "your work" included in the "products -completed operations hazard" under the following conditions: a) Only when you have agreed in writing to waive such rights of recovery in a contract or agreement; b) Only as to the person/entity as to whom you are required by the contract to waive rights of recovery; and c) Only if the contract or agreement is in effect during the term of this policy, and was executed by you prior to the loss. 6. Paragraph 10. is added as follows: 10. Liberalization If we revise this Coverage Form to provide more coverage without additional premium charge, your policy will automatically provide the additional coverage as of the day the revision is effective in the applicable state(s). CGL 088 (10 13) Includes copyrighted material of the Insurance Services Office, Inc., with its permission. Page 16 of 16 Copyright 2013 FCCI Insurance Group COMMERCIAL GENERAL LIABILITY CGL 084 (10 13) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU -ONGOING OPERATIONS AND PRODUCTS -COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM SCHEDULE OPTIONAL) Name of Additional Insured Persons or Organizations (As required by written contract or agreement per Paragraph A. below.) Locations of Covered Operations As per the written contract or agreement, provided the location is within the "coverage territory".) (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II —Who Is An Insured is amended to include as an additional insured: 1. Any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement in effect during the term of this policy that such person or organization be added as an additional insured on your policy; and 2. Any other person or organization you are required to add as an additional insured under the contractor agreement described in Paragraph 1. above; and 3. The particular person or organization, if any, scheduled above. Such person(s) or organization(s) is an additional insured only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" occurring after the execution of the contract or agreement described in Paragraph 1. above and caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf in the performance of your ongoing operations for the additional insured; or 3. Your work" performed for the additional insured and included in the "products -completed operations hazard" if such coverage is specifically required in the written contract or agreement. CGL 084 (10 13) Includes copyrighted material of the Insurance Services Offices, Inc. with its permission. Page 1 of 3 Copyright 2013 FCCI Insurance Group. COMMERCIAL GENERAL LIABILITY CGL 084 (10 13) However, the insurance afforded to such additional insureds) described above: 1. Only applies to the extent permitted by law; 2. Will not be broader than that which you are required by the contract or agreement to provide for such additional insured; 3. Will not be broader than that which is afforded to you under this policy; and 4. Nothing herein shall extend the term of this policy. B. The insurance provided to the additional insured does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or 2. Supervisory, inspection, architectural or engineering activities. C. This insurance is excess over any other valid and collectible insurance available to the additional insured whether on a primary, excess, contingent or any other basis; unless the written contract or agreement requires that this insurance be primary and non-contributory, in which case this insurance will be primary and non-contributory relative to insurance on which the additional insured is a Named Insured. D. With respect to the insurance afforded to these additional insureds, the following is added to Section 111 — Limits of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement described in Paragraph A.1.; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations, E. Section IV —Commercial General Liability Conditions is amended as follows: The Duties In The Event of Occurrence, Offense, Claim or Suit condition is amended to add the following additional conditions applicable to the additional insured: An additional insured under this endorsement must as soon as practicable: 1. Give us written notice of an "occurrence" or an offense which may result in a claim or "suit" under this insurance, and of any claim or "suit" that does result; It 2. Send us copies of all legal papers received in connection with the claim or suit", cooperate with us in the investAgation or settlement of the claim or defense against the "suit", and otherwise comply with all policy conditions; and 3. Tender the defense and indemnity of any claim or "suit" to any provider of other insurance which would cover the additional insured for a loss we cover under this endorsement and agree to make available all SUCH other insurance. However, this condition does not affect Paragraph C. above. CGL 084 (10 13) Includes copyrighted material of the Insurance Services Offices, Inc. with its permission. Page 2 of 3 Copyright 2013 FCCI Insurance Group. COMMERCIAL GENERAL LIABILITY CGL 084 (10 13) We have no duty to defend or indemnify an additional insured under this endorsement until we receive from the additional insured written notice of a claim or "suit". F. This endorsement does not apply to any additional insured or project that is specifically identified in any other additional insured endorsement attached to the Commercial General Liability Coverage Form, CGL 084 (10 13) Includes copyrighted material of the Insurance Services Offices, Inc. with its permission. Page 3 of 3 Copyright 2013 FCCI Insurance Group. 16.C.4.hPacket Pg. 1741Attachment: Checklist CC-J1 and J2 Jail Generator Validated - 03_04_2020 Signed (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1742 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1743 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1744 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1745 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1746 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1747 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) 16.C.4.i Packet Pg. 1748 Attachment: Bond (12980 : J1 - J2 Electrical Switchgear) Opinion of Cost Mr. Thomas Orr, Project Manager RE: Naples Jail J1 (Old Jail) and J2 (Administration) Electrical Work and Equipment – Phase 1 SUBJECT: Electrical Work and Equipment Bids Recommendation of Award Mr. Orr, After reviewing the Bid Solicitation posted on April 23rd, 2020 with the Detailed Scope of Work, Term of Contract of 180 days, and the Lump Sum Base Bid submitted on May 21st, 2020, we have the following results: ‐ Capital Contractors, LLC : $596,891.29 ‐ Compass Construction, Inc. : $621,866.00 ‐ EBL Partners : $499,779.15 All contractors were deemed responsible and within my original budget of $ 496,453. All bids were Lump Sum as per the Solicitation and in terms of the General Contracting Annual Agreement 19-7525. We did not request breakouts for Labor and Material or Subcontractors, but based on the totality of the bids received, I feel confident in their quality and would recommend award to EBL Partners as apparent low bidder. The results are consistent with my Opinion of Cost and within the parameters of the generated Budget. If you have further questions or need more information, please do not hesitate to contact my office. Thank you, John McCormick, PE Principal Facilities Engineer 16.C.4.j Packet Pg. 1749 Attachment: Naples Jail 1 Jail 2 - Opinion of Cost (12980 : J1 - J2 Electrical Switchgear) Electrical 9/14/2020 ITEM NO.QTY UNIT UNIT MAT. COST UNIT LAB. COST MAT. COST LAB. COST TOTAL COST UNIT COST W/ OH&P 1 1 Ea $400 $0 $400 $400 $400 2 60 LF $150 $0 $9,000 $9,000 $150 3 1 Ea $300 $0 $300 $300 $300 4 15 LF $10 $0 $150 $150 $10 5 15 LF $10 $0 $150 $150 $10 6 275 LF $36 $16 $10,010 $4,290 $14,300 $52 7 85 LF $36 $15 $3,035 $1,301 $4,335 $51 7 1 Ea $400 $0 $400 $400 $400 8 75 LF $25 $0 $1,875 $1,875 $25 8 280 LF $60 $26 $16,660 $7,140 $23,800 $85 9 90 LF $44 $19 $3,969 $1,701 $5,670 $63 10 270 Ea $105 $45 $28,350 $12,150 $40,500 $150 10 240 LF $18 $8 $4,368 $1,872 $6,240 $26 11 1 Ea $19,495 $8,355 $19,495 $8,355 $27,850 $27,850 12 1 Ea $21,211 $9,090 $21,211 $9,090 $30,301 $30,301 13 1 Ea $19,250 $8,250 $19,250 $8,250 $27,500 $27,500 14 1 LS $700 $300 $700 $300 $1,000 $1,000 15 64 LF $60 $26 $3,808 $1,632 $5,440 $85 16 25 LF $44 $19 $1,103 $473 $1,575 $63 17 80 LF $18 $8 $1,400 $600 $2,000 $25 17 1 Ea $3,000 $0 $3,000 $3,000 $3,000 18 90 LF $15 $0 $1,350 $1,350 $15 19 120 LF $84 $36 $10,080 $4,320 $14,400 $120 19 1 LS $25,000 $0 $25,000 $25,000 $25,000 20 1 EA $800 $0 $800 $800 $800 21 180 LF $15 $0 $2,700 $2,700 $15 22 1 Ea $300 $450 $300 $450 $750 $750 23 1 Ea $500 $1,500 $500 $1,500 $2,000 $2,000 24 2 Ea $5,740 $2,460 $11,480 $4,920 $16,400 $8,200 25 1 LS $2,100 $900 $2,100 $900 $3,000 $3,000 25 1 Ea $2,100 $900 $2,100 $900 $3,000 $3,000 26 1 Ea $1,050 $450 $1,050 $450 $1,500 $1,500 27 1 Ea $7,500 $0 $7,500 $7,500 $7,500 28 1 Ea $65,000 $0 $65,000 $0 $65,000 $65,000 SUBTOTAL 349,186 General Contractor OH&P $92,534 Mobilization $10,000 General Conditions $5,000 TOTAL $456,720 Naples Jail Power Back up for Building J1 and J2 - Phase 1 New wiring for relocated ATS 1 Remove and Relocate equipment on rack and wiring Furnish & Install 8 sets of # 500 Kcmil & 1 -500 kcmil gnd Furnish & Install 3 sets of # 400 Kcmil & 1#2/0 gnd Furnish and install 12-4" pvc SCH 40 empty conduits (20 ft ea) Furnish and install 3000 A main Furnish and install 3000 A Automatic Throw Over Furnish & Install 4000A Docking Station Trystar Furnish and install concrete slab for docking station & Swbd Furnish & Install 8 sets of # 500 Kcmil inside docking station Furnish & Install 3 sets of # 400 Kcmil inside docking station Remove existing Swbd empty cubicle Temporary MDP Remove existing ATS in generator room Relocate existing ground rod Relocate existing roof drain Wall openings Remove and Replace existing double doors Remove and Replace existing single door Patch and paint Wall openings Remove existing ATS wiring in generator room Probable Cost of Construction DESCRIPTION Remove and Relocate ATS 1 Remove wiring for relocated ATS 1 Remove existing docking station Removal of ATS (parking building) Wiring connection removal (J1 and J3) From main SWBD- EDP 225A Breaker removal Excavating feeders trench (16" wide & 24" deep) Furnish & Install 4" conduit PVC sch 80 exterior Backfill and compaction (16" wide & 24" deep) Remove existing docking station associated wiring Trapeze support Conductor terminations Furnish & Install 4" conduit GRS interior 16.C.4.k Packet Pg. 1750 Attachment: Collier Jail Atkins Probable Construction Cost Phase 1 (12980 : J1 - J2 Electrical Switchgear) Page 1 of 2 September 15, 2020 SENT VIA EMAIL Mr. Thomas Orr Project Manager Facilities Management Division Collier County Government 3335 Tamiami Trail East Naples, FL 34112-5356 RE: Naples Jail J1 (Old Jail) and J2 (Administration) Electrical Work and Equipment – Phase 1 SUBJECT: Electrical Work and Equipment Bids Recommendation of Award Mr. Orr: Atkins, under contract with Collier County Facilities Management Division for the bid phase of the referenced project, received copies of the lump sum base bids that Collier County received from three bidders, identified as Capital Contractors, LLC, Compass Construction, Inc, and EBL Partners. Atkins received the bidders single document that outlined the lump sum base bid amount, except for the ELB documents that included the two addenda and a Schedule of values. These documents constitute the limit of our evaluation. Due to the Corona virus (COVID-19), the work of the general contractors and their sub- contractors has been impacted, thus generating higher than normal construction costs. The submitted bids are lump sum and do not separate material from labor costs. The bids are as follows: • Capital Contractors, LLC - $596,891.29 • Compass Construction, Inc. - $621,866.00 • EBL Partners - $499, 779.15 After further review of the lump sum base bids provided to us, it is our opinion that the lump sum base bid from EBL Partners in the amount of $499,779.15 appears to be the lowest bid and appears to be reasonable when compared to Atkins $456,720 probable cost of construction, which is about 10% lower. Atkins recommends that the J1 (Old Jail) and J2 (Administration) Phase 1 electrical work and equipment bid be awarded to EBL Partners in the amount of $499,779.15. 16.C.4.l Packet Pg. 1751 Attachment: Collier County Naples Jail Electrical Bids recommendation (12980 : J1 - J2 Electrical Switchgear) Page 2 of 2 Mr. Thomas Orr September 14, 2020 J1 and J2 Electrical Work and Equipment Phase 1 Recommendation of Award Page 2 Please do not hesitate to contact me at: 305-514-3389 or by email at: Pedro.trevin@atkinsglobal.com Sincerely, Atkins Pedro L. Trevin, PE Principal Technical Professional Cc: John McCormick, PE – Collier County Jorge Fiallo, PE -Atkins 16.C.4.l Packet Pg. 1752 Attachment: Collier County Naples Jail Electrical Bids recommendation (12980 : J1 - J2 Electrical Switchgear)