Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Backup Documents 07/09/2019 Item #16B 3
ORIGINAL DOCUMENTS CHECKLIST & ROUTING SLI ' TO ACCOMPANY ALL ORIGINAL DOCUMENTS SEN r1E C E NED THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR SI NAT Print on pink paper. Attach to original document. The completed routing slip and original documents are to be forwarded to th4: u Office at the time the item is placed on the agenda. All completed routing slips and original documents must be received in the County Attorney Office no later than Monday preceding the Board meeting. **NEW** ROUTING SLIP Risk Management Complete routing lines#1 through#2 as appropriate for additional signatures,dates,and/or information needed. If the document is already complete with the exception of the Chairman's signature,draw a line through routing lines#1 through#2,complete the checklist,and forward to the County Attorney Office. Route to Addressee(s) (List in routing order) Office Initials Date 1. Risk Risk Management q�Q 2. County Attorney Office County Attorney Office 4. BCC Office Board of County {NbIYI b Commissioners J t} 7- (S 1 4. Minutes and Records Clerk of Court's Office 1-Ite 'RC1 r2 5. Procurement Services Procurement Services PRIMARY CONTACT INFORMATION Normally the primary contact is the person who created/prepared the Executive Summary. Primary contact information is needed in the event one of the addressees above,may need to contact staff for additional or missing information. Name of Primary Staff Ana Reynoso/PURCHASING Contact Information 239-252-8950 Contact/ Department Agenda Date Item was JULY 9, 2019 Agenda Item Number 16.B.3. Approved by the BCC Type of Document CONTRACT Number of Original 2 Attached Documents Attached PO number or account N/A 18-7466 AECOM number if document is AECOM TECHNICAL to be recorded TECHNICAL SERVICES, INC. SERVICES, INC. INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable column, whichever is Yes N/A(Not appropriate. (Initial) Applicable) 1. Does the document require the chairman's original signature STAMP OK N/A 2. Does the document need to be sent to another agency for additional signatures? If yes, N/A provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be AR signed by the Chairman,with the exception of most letters,must be reviewed and signed by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the AR document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's AR signature and initials are required. 7. In most cases(some contracts are an exception),the original document and this routing slip N/A should be provided to the County Attorney Office at the time the item is input into SIRE. Some documents are time sensitive and require forwarding to Tallahassee within a certain time frame or the BCC's actions are nullified. Be aware of your deadlines! 8. The document was approved by the BCC on 07/9/2019 and all changes made during a the meeting have been incorporated in the attached document. The County i Attorney's Office has reviewed the changes,if applicable. 9. Initials of attorney verifying that the attached document is the version approved by the BCC,all changes directed by the BCC have been made,and the document is ready for the Q'C` Chairman's signature. 1683 MEMORANDUM Date: July 16, 2019 To: Ana Reynoso, Purchasing Tech Procurement Services From: Ann Jennejohn, Deputy Clerk Minutes & Records Department Re: Contract #18-7466: Construction Engineering Inspection (CEI) Services for the Thomasson Drive Beautification Project Contractor: AECOM Technical Services, Inc. Attached, is an original copy of the contract referenced above, (Item #16B3) approved by the Board of County Commissioners on Tuesday, July 9, 2019. The second original contract has been held in the Minutes and Records Department for the Board's Official Record. If you have any questions, please contact me at 252-8406. Thank you. Attachment 1683 PROFESSIONAL SERVICES AGREEMENT Contract# 18-7466 for CEI Services for Thomasson Drive Beautification Project CCNA ❑ NON-CCNA THIS AGREEMENT is made and entered into this \day of 2019 by and between the Board of County Commissioners for Collie ounty, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and AECOM Technical Services, Inc. , authorized to do business in the State of Florida, whose business address is 4415 Metro Parkway, Suite 404, Fort Myers, FL 33916 (hereinafter referred to as the "CONSULTANT" and/or"CONTRACTOR"). WITNESSETH: WHEREAS, the COUNTY desires to obtain the professional services of the CONSULTANT concerning CEI Services for Thomasson Drive Beautification Project(hereinafter referred to as the "Project"), said services being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and; WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows: ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to COUNTY professional services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the COUNTY for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards and other Page 1 of 32 PSA Single Project Agreement 2017.010 Ver.1 C 16B3 governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to the COUNTY. 1.5. CONSULTANT designates Crystal Gorman, P.E. a qualified licensed professional to serve as the CONSULTANT's project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without the COUNTY's prior written approval, and if so removed must be immediately replaced with a person acceptable to the COUNTY. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from the COUNTY to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to the COUNTY. 1.7. The CONSULTANT represents to the COUNTY that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the COUNTY's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Page 2 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following the COUNTY's address of record: Board of County Commissioners for Collier County, Florida Division Director: Debrah Forester Division Name: Community Redevelopment Agency Address: 3750 Bayshore Drive, Unit 102 Naples, Florida 34112 Administrative Agent/PM: Tami Scott, Senior Project Manager Telephone: (239) 643-1115 E-Mail(s): Tami.Scott@colliercountyfl.gov 16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT's address of record: Company Name: AECOM Technical Services, Inc. Address: 4415 Metro Parkway, Suite 404 Fort Myers, FL 33916 Authorized Agent: J. Larry Sauls, P.E. Attention Name & Title: Telephone: (813) 286-1711 E-Mail(s): Larry.Sauls@aecom.com Page 13 of 32 PSA Single Project Agreement 2017.010 Ver.1 16B3 Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 1.8. In the event of any conflicts in these requirements, the CONSULTANT shall notify the COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY regarding resolution of each such conflict. The COUNTYS approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project. 1.9. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to CONSULTANT's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY reserves the right to make sole determination regarding deductions. After notification of deficiency, if the CONSULANT fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge the Page 3 of 32 PSA Single Project Agreement 2017 010 Ver.1 ce. 1683 CONSULTANT for services and/or items necessary to correct the deficiencies directly related to the CONSULTANT's non-performance whether or not the COUNTY obtained substitute performance. 1.10. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without the COUNTY's prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt written notice of any such subpoenas. 1 .11. As directed by the COUNTY, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real- Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have common naming conventions (i.e. right-of-way- ROW, centerlines - CL, edge-of-pavement- EOP, etc.), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT 2.1 . If authorized in writing by the COUNTY through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in the COUNTY's Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by the COUNTY as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. The COUNTY will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If the COUNTY determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to the COUNTY of the emergency within forty-eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT's right it otherwise may have had to seek an adjustment to its compensation or time of performance under this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: Page 4 of 32 PSA Single Project Agreement 2017.010 Ver.1 0 1683 2.2. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.3. Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, the COUNTY's schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by the COUNTY when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT's control and fault. 2.4. Providing renderings or models for the COUNTY's use. 2.5. Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting the COUNTY in obtaining such process licensing. 2.6. Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.7. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by the COUNTY, other than visits to the Project site or the COUNTY's office. 2.8. Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2.9. Preparing to serve or serving as a CONSULTANT or witness for the COUNTY in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as part of the Basic Services to be provided herein). 2.10. Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice. ARTICLE THREE THE COUNTY'S RESPONSIBILITIES 3.1. The COUNTY shall designate in writing a project manager to act as the COUNTY's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define the COUNTY's policies and decisions with respect to CONSULTANT's services for the Project. However, the Project Manager is not authorized to issue any verbal or written orders or instructions to the CONSULTANT that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: Page 5 of 32 PSA Single Project Agreement 2017.010 Ver.I 1683 a. The scope of services to be provided and performed by the CONSULTANT hereunder; b. The time the CONSULTANT is obligated to commence and complete all such services; or c. The amount of compensation the COUNTY is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: a. Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; b. Provide all criteria and information requested by CONSULTANT as to the COUNTY 's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; c. Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT's disposal all available information in the COUNTY's possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; d. Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the COUNTY with respect to the services to be rendered by CONSULTANT hereunder. ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from the COUNTY for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT's services from any cause whatsoever, including those for which the COUNTY may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from the COUNTY. CONSULTANT's sole remedy against the COUNTY will be the right to seek an extension of time Page 6 of 32 PSA Single Project Agreement 2017.010 Ver.l 1663 to its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT's compensation shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the COUNTY's satisfaction that the CONSULTANT's performance is or will shortly be back on schedule. 4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by the COUNTY to CONSULTANT be deemed a waiver of any right or claim the COUNTY may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the COUNTY for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction of the COUNTY's Project Manager before payment for the fixed price contract is authorized. Time and Materials: The COUNTY agrees to pay the contractor for the amount of labor time spent by the CONSULTANT 's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's mark-up). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. 5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above. U Grant Funded: The hourly rates as set forth and identified in Schedule Page 7 of 32 PSA Single Project Agreement 2017.010 Ver.1 # c 1683 B, which is attached hereto, are for purposes of providing estimate(s), as required by the grantor agency. ARTICLE SIX THE OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by the COUNTY, CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement("Project Documents"). The COUNTY shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to the COUNTY the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring the COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use on this Project. CONSULTANT warrants to the COUNTY that it has full right and authority to grant this license to the COUNTY. Further, CONSULTANT consents to the COUNTY's use of the Project Documents to complete the Project following CONSULTANT's termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges the COUNTY may be making Project Documents available for review and information to various third parties and hereby consents to such use by the COUNTY. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder. The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall defend, indemnify and hold harmless the COUNTY, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce Page 8 of 32 PSA Single Project Agreement 2017 010 Ver.l 168 3 any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 8.1.1. The duty to defend under this Article 8 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the CONSULTANT, the COUNTY and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to CONSULTANT. The CONSULTANT's obligation to indemnify and defend under this Article 8 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the COUNTY or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2. All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3. All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests' provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against the COUNTY for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by the COUNTY applicable to this Project. 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. Page 9 of 32 PSA Single Project Agreement 2017.010 Ver.1 0 1683 9.4. CONSULTANT, its subconsultants and the COUNTY shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by the COUNTY, except such rights as they may have to the proceeds of such insurance held by any of them. 9.5. All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements: 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff, unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this Agreement shall, however, be construed as constituting an agreement between the COUNTY and any such other person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third party any claim or right of action against the COUNTY beyond such as may then otherwise exist without regard to this Agreement. 10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. All personnel, identified in Schedule F shall not be removed or replaced without the COUNTY's prior written consent. 10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the COUNTY. Each subconsultant or subcontract agreement shall preserve and protect the rights of the COUNTY under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the sub consulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub- subconsultants or sub-subcontractors. 10.4. CONSULTANT acknowledges and agrees that the COUNTY is a third-party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between the COUNTY and any subconsultant or subcontractor. Further, all such contracts shall Page 10 of 32 PSA Single Project Agreement 2017 010 Ver.1 16B3 provide that, at the COUNTY's discretion, they are assignable to the COUNTY upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS 11.1. CONSULTANT's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the COUNTY arising out of this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANT's services nor payment by the COUNTY shall be deemed to be a waiver of any of the COUNTY's rights against CONSULTANT. ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for the COUNTY to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT's failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT's failure to properly and timely perform the services to be provided hereunder or as directed by the COUNTY, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT's principals, officers or directors, or (d) CONSULTANT's failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT's failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The COUNTY may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below. 12.3. The COUNTY shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such termination for convenience, CONSULTANT'S recovery against the COUNTY shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against the COUNTY, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. Page 11 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 12.4. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the COUNTY all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Article 6, that are in CONSULTANT's possession or under its control. 12.5. The COUNTY shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 12.6. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) the COUNTY otherwise persistently fails to fulfill some material obligation owed by the COUNTY to CONSULTANT under this Agreement, and (ii) the COUNTY has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving THE COUNTY a second fourteen (14) days written notice of CONSULTANT's intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to the COUNTY of CONSULTANT's intent to terminate this Agreement. If the COUNTY does not cure its default within fourteen (14) days after receipt of CONSULTANT's written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the COUNTY, terminate the Agreement and recover from the COUNTY payment for Services performed through the termination date, but in no event, shall CONSULTANT be entitled to payment for Services not performed or any other damages from the COUNTY. ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. 13.2. I■ CCNA Projects: In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs supporting the compensation for CONSULTANT's services to be provided under this Agreement are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees that the original Agreement price and any additions thereto shall be adjusted to exclude any significant sums by which the COUNTY determines the Agreement price was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit costs. All such adjustments shall be made within one (1) year following the end of this Agreement. Page 12 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following the COUNTY's address of record: Board of County Commissioners for Collier County, Florida Division Director: Debrah Forester Division Name: Community Redevelopment Agency Address: 3750 Bayshore Drive, Unit 102 Naples, Florida 34112 Administrative Agent/PM: Tami Scott, Senior Project Manager Telephone: (239) 643-1115 E-Mail(s): Tami.Scott@colliercountyfl.gov 16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT's address of record: Company Name: AECOM Technical Services, Inc. Address: 16000 Old 41 Road, Unit 211 Naples, Florida 34110 Authorized Agent: J. Larry Sauls, P.E. Attention Name & Title: Telephone: (239) 250-6680 E-Mail(s): Larry.Sauls@gmail.com Page 13 of 32 PSA Single Project Agreement 2017.010 Ver.l 6 3 16.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. ARTICLE SEVENTEEN MISCELLANEOUS 17.1. CONSULTANT, in representing the COUNTY, shall promote the best interests of the COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair dealing. 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of the COUNTY. 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 17.8. This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 17.9. The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE Schedule E CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE Schedule F KEY PERSONNEL Schedule G Other: n/a Solicitation # 18-7466 , including all Attachment(s), Exhibit(s) &Addendum Consultant's Proposal Page 14 of 32 PSA Single Project Agreement 2017.010 Ver.l 16B3 17.10. n Grant Funded Projects: In the event of any conflict between or among the terms of any of the Contract Documents and/or the COUNTY's Board approved Executive Summary, the terms of the Agreement shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Grant Conditions shall take precedence over the Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved by application of the Supplemental Conditions, if any, or the Agreement, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the CONSULTANT at the COUNTY's discretion. 17.11. Applicability. Sections corresponding to any checked box (U ) expressly apply to the terms of this Agreement. ARTICLE EIGHTEEN APPLICABLE LAW 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE NINETEEN SECURING AGREEMENT/PUBLIC ENTITY CRIMES 19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. • At the time this Agreement is executed, CONSULTANT shall sign and deliver to the COUNTY the Truth-In-Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E. CONSULTANT's compensation shall be adjusted to exclude any sums by which the COUNTY determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity, may not be Page 15 of 32 PSA Single Project Agreement 2017 010 Ver.1 C 1663 awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." ARTICLE TWENTY DISPUTE RESOLUTION 20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached during negotiations to the COUNTY for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached at mediation to the COUNTY's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 20.2. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE 21 IMMIGRATION LAW COMPLIANCE 21.1. By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the COUNTY shall have the discretion to unilaterally terminate this Agreement immediately. (signature page to follow) Page 16 of 32 PSA Single Project Agreement 2017 010 Ver.l 1683 IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement the day and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS FOR COLLIER COUNTY, FLORIDA, Crystal K. r 1, kIerk of Courts & Comptroll '• , zs• olkfr By: W . .. . �SiC.. Date:A By:yl W'T iam L. McDaniel Jr. , Chairman stgnatigonly. pro ed as to •r and Legality: 1i' County Attorney Name Consultant: Consultant's Witnesses: AECOM Tech,ical Servi es Inc t MM ilti(jt By: (� Witness "� /'I � � ,406.t. h-vLS VIft f•2r�5112/5.--7 Name and Title Name and Title a. Witn ss Yoot¢.5 Co 5 4.e.s-i r m 4o►� Name and Title 13 & O a Page 17 of 32 PSA Single Project Agreement 2017.010 Ver S� 1683 SCHEDULE A SCOPE OF SERVICES 1 12 following this page (pages through ) Page 18 of 32 PSA Single Project Agreement 2017.010 Ver.1 C 1683 18-7466 "CEI Services for Thomasson Drive Beautification Project" SCHEDULE A SCOPE OF SERIVICES 1.0 PURPOSE: This scope of services describes and defines the Construction Engineering and Inspection (CEI) services which are required for constructability review, value engineering, contract administration, inspection, and materials sampling and testing for the construction project listed below. 2.0 SCOPE: The project for which the services are required are: Descriptions: Roadway Improvement Construction will be according to Improvements of Thomasson Dr. and Hamilton Ave. documents prepared RWA Engineering, Inc., County: Collier Exercise independent professional judgment in performing obligations and responsibilities under this Agreement. Pursuant to Section 4.1.4 of the Construction Project Administration Manual (CPAM), the authority of the Consultant's lead person, such as the Senior Project Engineer, and the Consultant's Project Administrator shall be identical to the Collier County Construction Management Department and shall be interpreted as such. Services provided by the Consultant shall comply with FDOT and collier county manuals/standards, procedures, and memorandums in effect as of the date of execution of the Agreement unless otherwise directed in writing by the County. Such FDOT manuals, procedures, and memorandums are found at the State Construction Office's website. 3.0 LENGTH OF SERVICE: CEI contract will begin a minimum of 3 month prior to the construction contract NTP and will end 2 months after construction completion. The services for each Construction Contract shall begin upon written notification to proceed by the County. The County Construction Project Manager shall track the execution of the Construction Contract such that the Consultant is given timely authorization to begin work. While no personnel shall be assigned until written notification by the County has been issued, the Consultant shall be ready to assign personnel within two weeks of notification. For the duration of the project, coordinate closely with the County and Contractor to minimize rescheduling of Consultant activities due to construction delays or changes in scheduling of Contractor activities. The anticipated letting schedules and construction times for the project 365 days from notice to proceed. 4.0 DEFINITIONS: A. Agreement: The Professional Services Agreement between the County and the Consultant setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of services, and the basis of payment. B. Contractor: The individual, firm, or company contracting with the County for performance of work or furnishing of materials. Page 1 of 12 Schedule A-Scope of Services 16B3 C. Construction Contract: The written agreement between the County and the Contractor setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of labor and materials, and the basis of payment. D. Construction Project Manager: The County employee assigned to manage the Construction Engineering and Inspection Contract and represent the County during the performance of the services covered under this Agreement. E. Construction Training/Qualification Program (CTQP): The Department program for training and qualifying technicians in Aggregates, Asphalt, Concrete, Earthwork, and Final Estimates Administration. Program information is available at CTQP website. F. Consultant: The Consulting firm under contract to the County for administration of Construction Engineering and Inspection services. G. Consultant Project Administrator: The employee assigned by the Consultant to be in charge of providing Construction Contract administration services for one or more Construction Projects. H. Consultant Senior Project Engineer: The Engineer assigned by the Consultant to be in charge of providing Construction Contract administration for one or more Construction Projects. This person may supervise other Consultant employees and act as the lead Engineer for the Consultant. I. County Construction Manager: The administrative head of the Construction Management Department J. Director of Transportation Operations: The Director of Construction, Maintenance, Traffic Operations, Materials, and Safety. K. Division Administrator: The Administrative Head of the County's Growth Management Division. L. Engineer of Record: The Engineer noted on the Construction plans as the responsible person for the design and preparation of the plans. M. FDOT Operations Engineer: The Engineer assigned to a particular County or area to admin- ister Construction and Maintenance Contracts for the FDOT. N. Public Information Officer: The County employee assigned to manage the Public Information Program. O. Resident Compliance Specialist: The employee assigned by the Consultant to oversee project specific compliance functions. P. Resident Engineer: The Engineer assigned to a particular County or area to administer Construction Contracts for the Department. Q. Owner: The Board of County Commissioners for Collier County. Florida. A political subdivision of the State of Florida. R. County: Collier County, a political subdivision of the State of Florida. Page 2 of 12 Schedule A-Scope of Services 5.0 ITEMS TO BE FURNISHED BY THE COUNTY TO THE CONSULTANT: 1 6 B 3 A. The County, on an as needed basis, will furnish the following Construction Contract documents for this project. These documents may be provided in either paper or electronic format. 1. Construction Plans, 1 hard copy sets in size 11"x 17" 2. Specification Package, 1 hard copy sets in size 81/2" x 11" 3. Copy of the Executed Construction Contract, 1 hard copy and 4. Utility Agency's Approved Material List (if applicable). 5. Executed Utility Work Schedules (if applicable) B. A list of all standard forms for use under the terms of this Agreement will be provided in hard copy at the Pre-Services meeting. All directives, procedures, and Standard Forms can be accessed through the County's Internet website. 6.0 ITEMS FURNISHED BY THE CONSULTANT: NA 6.1 FDOT DOCUMENTS: All applicable FDOT documents referenced herein shall be a condition of this Agreement. All FDOT documents, directives, procedures, and standard forms are available through the FDOT's Internet website. Most items can be purchased through the following address. All others can be acquired through the District Office or on-line at the Department's website. Florida Department of Transportation Maps and Publication Sales 605 Suwannee Street, MS 12 Tallahassee, Florida 32399-0450 Telephone No. (850)488-9220 http://www.dot.state.fl.us/construction/ 6.2 OFFICE AUTOMATION: Provide all software and hardware necessary to efficiently and effectively carry out the responsibilities under this Agreement. Provide each inspection staff with a laptop computer running software needed for project scheduling, documentation, and control (such as, Site Manager application through Citrix, Primavera/Sidetrack, Claim Digger, etc.) connection using a mobile broadband connection at the jobsite. All computer coding shall be input by Consultant personnel using equipment furnished by them. Ownership and possession of computer equipment and related software, which is provided by the Consultant, shall remain at all times with the Consultant. The Consultant shall retain responsibility for risk of loss or damage to said equipment during performance of this Agreement. Field office equipment should be maintained and operational at all times. Current technical specifications for office automation can be viewed at: http://www.dot.state.fl.us/Construction/DesignBuild/ConsultantCEl/OfficeAutomation.shtm Page 3 of 12 Schedule A-Scope of Services 1683 6.3 VEHICLES: Vehicles will be equipped with appropriate safety equipment and must be able to effectively carry out requirements of this Agreement. Vehicles shall have the name and phone number of the consulting firm visibly displayed on both sides of the vehicle. 6.4 FIELD EQUIPMENT: Supply survey, inspection, and testing equipment essential to perform services under this Agreement; such equipment includes non-consumable and non-expendable items. Hard hats shall have the name of the consulting firm visibly displayed. Equipment described herein and expendable materials under this Agreement will remain the property of the Consultant and shall be removed at completion of the work. Handling of nuclear density gauges shall be in compliance with their license. Retain responsibility for risk of loss or damage to said equipment during performance of this Agreement. Field office equipment shall be maintained and in operational condition at all times. 6.5 LICENSING FOR EQUIPMENT OPERATIONS: Obtain proper licenses for equipment and personnel operating equipment when licenses are required. The license and supporting documents shall be available for verification by the County, upon request. Radioactive Materials License for use of Surface Moisture Density Gauges shall be obtained through the State of Florida Department of Health. 7.0 LIAISON RESPONSIBILITY OF THE CONSULTANT: For the duration of the Agreement, consultant must keep the County's Construction Project Manager informed of all significant activities, decisions, correspondence, reports, and other communications related to its responsibilities under this Agreement. Facilitate communications between all parties (i.e. architectural, mechanical, materials, landscaping, local agencies, etc.) ensuring responses and resolutions are provided in a timely manner. Maintain accurate records to document the communication process. Submit all administrative items relating to Invoice Approval, Personnel Approval, User IDs, Time Extensions, change orders and Supplemental Amendments to the Construction Project Manager for review and approval. 8.0 PERFORMANCE OF THE CONSULTANT: During the term of this Agreement and all Supplemental Amendments thereof, the County will review various phases of Consultant operations, such as construction inspection, materials sampling and testing, and administrative activities, to determine compliance with this Agreement. Cooperate and assist County representatives in conducting the reviews. If deficiencies are indicated, remedial action shall be implemented immediately. County recommendations and Consultant responses/actions are to be properly documented by the Consultant. No additional compensation shall be allowed for remedial action taken by the Consultant to correct deficiencies. Remedial actions and required response times may include but are not necessarily limited to the following: A. Further subdivide assigned inspection responsibilities, reassign inspection personnel, or assign additional inspection personnel, within one week of notification. Page 4 of 12 Schedule A-Scope of Services B. Immediately replace personnel whose performance has been determined by the C"onnulfant and/or the County to be inadequate. C. Immediately increase the frequency of monitoring and inspection activities in phases of work that are the Consultant's responsibility. D. Increase the scope and frequency of training of the Consultant personnel. 9.0 REQUIREMENTS OF THE CONSULTANT: 9.1 GENERAL: It shall be the responsibility of the Consultant to administer, monitor, and inspect the Construction Contract such that the project is constructed in reasonable conformity with the plans, specifications, and special provisions for the Construction Contract. Observe the Contractor's work to determine the progress and quality of work. Identify discrepancies, report significant discrepancies to the County, and direct the Contractor to correct such observed discrepancies. Consult with the Construction Project Manager as necessary and direct all issues, which exceed delegated authority to the Construction Project Manager for action or direction. Inform the Construction Project Manager of any significant omissions, substitutions, defects, and deficiencies noted in the work of the Contractor and the corrective action that has been directed to be performed by the Contractor. 9.2 SURVEY CONTROL: Check or establish the survey control baseline(s) along with sufficient baseline control points and bench marks at appropriate intervals along the project in order to: (1) make and record measurements necessary to calculate and document quantities for pay items, (2) make and record pre-construction and final cross section surveys of the project site in those areas where earthwork (i.e., embankment, excavation, subsoil excavation, etc.) is part of the construction project, and (3) perform incidental engineering surveys. 9.3 ON-SITE INSPECTION: Monitor the Contractor's on-site construction activities and inspect materials entering into the work in accordance with the plans, specifications, and special provisions for the Construction Contract to determine that the projects are constructed in reasonable conformity with such documents. Maintain detailed accurate records of the Contractor's daily operations and of significant events that affect the work. The Consultant will monitor off-site activities and fabrication unless otherwise stipulated by this Agreement. Monitor and inspect Contractor's Work Zone Traffic Control Plan and review modifications to the Work Zone Traffic Control Plan, including Alternate Work Zone Traffic Control Plan, in accordance with the FDOT's procedures. Consultant employees performing such services shall be qualified in accordance with the FDOT's guidelines of Traffic Training (Topic No. 625- 010-010-a) 9.4 SAMPLING AND TESTING: Perform sampling and testing in conjunction with an independent, licensed laboratory, whose selection has been approved in writing by the Construction Project Manager, hired by the Consultant, sampling and testing of component materials and completed work items so that the materials and workmanship incorporated in the project are in reasonable conformity with Page 5 of 12 Schedule A-Scope of Services the plans, specifications and contract provisions. The minimum sampling freasset out in the FDOT's Materials Sampling, Testing and Reporting Guide shall be met. In complying with the aforementioned guide, provide daily surveillance of the Contractor's Quality Control activities and perform the sampling and testing of materials and completed work items for verification and acceptance. The Consultant will perform inspection and sampling of materials and components at locations remote from the project site and perform testing of materials normally done in a laboratory remote from the project site. Determine the acceptability of all materials and completed work items on the basis of either test results or verification of a certification, certified mill analysis, DOT label, DOT stamp, etc. The County will monitor the effectiveness of the Consultant's testing procedures through observation and independent assurance testing. Sampling, testing and laboratory methods shall be as required by the FDOT's Standard Specifications, Supplemental Specifications or as modified by the Special Provisions of the Construction Contract. Documentation reports on sampling and testing performed by the Consultant shall be submitted during the same week that the construction work is done. Transport laboratory samples to the appropriate laboratory. The Consultant shall provide daily surveillance of the Contractor's Quality Control activities at the project site in regard to concrete and perform acceptance sampling at the specified frequency. Supply CTQP (Construction Training Qualification Program) qualified technicians for concrete inspection. Supply CTQP qualified Asphalt Paving and Plant Technicians for asphalt inspection. Supply CTQP qualified Earthwork Construction Inspection Technicians for embankment, pipe backfill, subgrade, base and asphalt inspection. 9.5 ENGINEERING SERVICES: Prior to commencement of construction and immediately after award of CEI contract, the consultant is to review all Construction documents and provide a written constructability review and value engineering report to the Collier County Project Manager. During Construction the Consultant shall coordinate the Construction Contract administration activities of all parties other than the Contractor involved in completing the construction project. Services shall include maintaining the required level of surveillance of Contractor activities, interpreting plans, specifications, and special provisions for the Construction Contract. Maintain complete, accurate records of all activities and events relating to the project and properly document all project changes. The following services shall be performed: (1) Attend pre-bid meeting and review the bid submittals. (2) Attend a pre-service meeting for the Agreement within ten (10) business days after the Notice-to- Proceed in accordance with Procedure 700-000-000-a. Provide appropriate staff to attend and participate in the pre-service meeting. At the pre-service meeting the CONSULTANT shall submit Action Request packages for Personnel Approval for immediate staff needs and a copy/ computer file of the final negotiated staffing. The CONSULTANT shall record a complete and concise record of the proceedings of the meeting and distribute copies of these minutes to the participants and other interested parties within seven (7) days of the meeting date. Page 6 of 12 Schedule A-Scope of Services (3) Prepare and submit to the Construction Project Manager for county apjgo6a Ai in thirty (30) days after the pre-service meeting, a hard copy of the project specific CONSULTANT Contract administration documents listed below. The CONSULTANT Contract administration documents, which shall be routinely used by the CONSULTANT throughout the project, shall be in the format and content provided by Collier County Construction Management Department. The CONSULTANT Contract administration documents consist of but are not limited to the documents listed below: a. Action Request Form b. Contract Status Report, or other approved fund tracking report c. CEI CONSULTANT Firm Estimated Staffing (completed in accordance with the original CONSULTANT Contract agreement) d. CEI CONSULTANT Fee Proposal e. CEI CONSULTANT Data (4) Schedule and conduct a Pre-construction conference in accordance with Article 8-3.5 of the FDOT Standard Specification for Road and Bridge Construction. The purpose of the meetings is to discuss the required documentation, including as-builts, necessary for permit(s) compliance. Record significant information revealed and decisions made at this conference and distribute copies of these minutes to the appropriate parties. The meeting shall also be electronically recorded and the CONSULTANT shall maintain all tapes of the meeting for the duration of the Contract. (4) Consultant should organize and conduct Monthly progress meetings, set the agenda, record and provide minutes. (5) Verify that the Contractor is conducting inspections, preparing reports and monitoring all storm water pollution prevention measures associated with the project. For each project that requires the use of the NPDES General Permit, provide at least one inspector who has successfully completed the "Florida Stormwater, Erosion, and Sedimentation Control Training and Certification Program for Inspectors and Contractors". The Consultant's inspector will be familiar with the requirements set forth in the FEDERAL REGISTER, Vol. 57, No. 187, Friday, September 5, 1992, pages 4412 to 4435 "Final NPDES General Permits for Storm Water Discharges from Construction Sites" and the Department's guidelines. Coordinate with the Contractors Public Information Officer to assure updated information and MOT issues are communicated to the public. (6) Analyze the Contractor's schedule(s) (i.e. baseline(s), revised baseline(s), updates, as-built, etc.) for compliance with the contract documents. Elements including, but not limited to, completeness, logic, durations, activity, flow, milestone dates, concurrency, resource allotment, and delays will be reviewed. Verify the schedule conforms with the construction phasing and MOT sequences, including all contract modifications. Provide a written review of the schedule identifying significant omissions, improbable or unreasonable activity durations, errors in logic, and any other concerns as detailed in CPAM. (7) Analyze problems that arise on a project and proposals submitted by the Contractor; work to resolve such issues, and process the necessary paperwork. (8) Monitor, inspect and document utility construction for conformance with Utility Agency's Standards and the Utility Agency's Approved Materials List. Facilitate coordination and communication between Utility Agency's representatives, Department's staff and Contractors executing the work. Identify potential utility conflicts and assist in the resolution of utility issues including Department and Local Government owned facilities. Page 7 of 12 Schedule A-Scope of Services 1 B3 Identify, review, and track progress of Joint Project Agreements, and/or other Department and utility agreements. Address work progress, track reimbursement activities, and address betterment and salvage determination. Prepare all necessary documentation to support reimbursement activities and betterment and salvage determination. (9) Produce reports, verify quantity calculations and field measure for payment purposes as needed to prevent delays in Contractor operations and to facilitate prompt processing of such information in order for the Department to make timely payment to the Contractor. (10) Prepare and make presentations for meetings and hearings before the Dispute Review Boards in connection with the project covered by this Agreement. (11) Monitor each Contractor and Subcontractor's compliance with specifications and special provisions of the Construction Contract in regard to payment of predetermined wage rates in accordance with FDOT procedures. (12) Prepare and submit to the Construction Project Manager monthly, a Construction Status Reporting System (CSRS) report, in a format to be provided by the County. (13) Video tape the pre-construction conditions throughout the project limits. Provide a digital photo log or video of project activities, with heavy emphasis on potential claim items/issues and on areas of real/potential public controversy. (14) Provide a digital camera for photographic documentation of pre-construction state and of noteworthy incidents or events during construction. Photos should be provided monthly to show progress. These photographs will be filed and maintained on the Consultant's computer using a Digital Photo Management system. Photographs shall be taken the day prior to the start of construction and continue as needed throughout the project. Photographs shall be taken the days of Conditional, Partial and Final Acceptance. 10.0 GENERAL REQUIREMENTS: Provide qualified personnel necessary to efficiently and effectively carry out its responsibilities under this Agreement. 10.1 PERSONNEL QUALIFICATIONS: Provide competent personnel qualified by experience and education. Submit in writing to the Construction Project Manager the names of personnel proposed for assignment to the project, including a detailed resume for each containing at a minimum: salary, education, and experience. The Consultant Action Request form for personnel approval shall be submitted to the Construction Project Manager at least two weeks prior to the date an individual is to report to work. Personnel identified in the Consultant technical proposal are to be assigned as proposed and are committed to performing services under this Agreement. Personnel changes will require written approval from the Construction Project Manager. Staff that has been removed shall be replaced by the Consultant within one week of Construction Project Manager Notification. Before the project begins, all project staff shall have a working knowledge of the current CPAM and must possess all the necessary qualifications/certifications for fulfilling the duties Page 8 of 12 Schedule A-Scope of Services 1683 of the position they hold. Cross training of the Consultant's project staff is highly recommended to achieve a knowledgeable and versatile project inspection team but shall not be at any additional cost to the County and should occur as workload permits. Visit the training page on the State Construction Office website for training dates. Minimum qualifications for the Consultant personnel are set forth as follows. Exceptions to these minimum qualifications will be considered on an individual basis. However, a Project Administrator working under the supervision and direction of a Senior Project Engineer or an Inspector working under the supervision and direction of a Senior Inspector shall have six months from the date of hire to obtain the necessary qualifications/certifications provided all other requirements for such positions are met and the Consultant submits a training plan detailing when such qualifications/certifications and other training relative to the FDOT's procedures, Specifications and Design Standards will be obtained. The County Construction Manager or designee will have the final approval authority on such exceptions. It is preferred that the Senior Project Engineer assigned to the project have prior experience in roundabout construction and advanced MOT. 10.2 STAFFING: Once authorized, the Consultant shall establish and maintain appropriate staffing throughout the duration of construction and completion of the final estimate. Responsible personnel, thoroughly familiar with all aspects of construction and final measurements of the various pay items, shall be available to resolve disputed final pay quantities until the County has received a regular acceptance letter. Construction engineering and inspection forces will be required of the Consultant while the Contractor is working. If Contractor operations are substantially reduced or suspended, the Consultant will reduce its staff appropriately. In the event that the suspension of Contractor operations requires the removal of Consultant forces from the project, the Consultant will be allowed ten (10) days maximum to demobilize, relocate, or terminate such forces. 11.0 QUALITY ASSURANCE (QA) PROGRAM: 11.1 QUALITY ASSURANCE PLAN: Within thirty (30) days after receiving award of an Agreement, furnish a QA Plan to the Construction Project Manager. The QA Plan shall detail the procedures, evaluation criteria, and instructions of the Consultant's organization for providing services pursuant to this Agreement. Unless specifically waived, no payment shall be made until the County approves the Consultant QA Plan. Significant changes to the work requirements may require the Consultant to revise the QA Plan. It shall be the responsibility of the Consultant to keep the plan current with the work requirements. The Plan shall include, but not be limited to, the following areas: A. Organization: A description is required of the Consultant QA Organization and its functional relationship to the part of the organization performing the work under the Agreement. The authority, responsibilities and autonomy of the QA organization shall be detailed as well as the names and qualifications of personnel in the quality control organization. B. Quality Assurance Reviews: Detail the methods used to monitor and achieve organization compliance with Agreement requirements for services and products. Page 9 of 12 Schedule A-Scope of Services C. Quality Assurance Records: 16 B 3 Outline the types of records which will be generated and maintained during the execution of the QA program. D. Control of Subconsultants and Vendors: Detail the methods used to control subconsultant and vendor quality. E. Quality Assurance Certification: An officer of the Consultant firm shall certify that the inspection and documentation was done in accordance with FDOT specifications, plans, standard indexes, and Department procedures. 11.2 QUALITY ASSURANCE REVIEWS: The CCEI shall perform an initial QA review within the first two (1) months of the start of construction. 11.3 QUALITY RECORDS: Maintain adequate records of the quality assurance actions performed by the organization (including subcontractors and vendors) in providing services and products under this Agreement. All records shall indicate the nature and number of observations made, the number and type of deficiencies found, and the corrective actions taken. All records shall be available to the Department, upon request, during the Agreement term. All records shall be kept at the primary job site and shall be subject to audit review. 12.0 CERTIFICATION OF FINAL ESTIMATES: 12.1 FINAL ESTIMATE AND AS-BUILT PLANS SUBMITTAL: Prepare documentation and records in compliance with the Agreement, Statewide Quality Control (QC) Plan, or Consultant's approved QC Plan and the FDOT's Procedures as required by Section 4.1.4 of Review and Administration Manual. Submit the Final Estimate(s) and one (1) set of final "as-built plans"documenting the Contractor's work in accordance with the Review and Administration Manual. Revisions to the Certified Final Estimate will be made at no additional cost to the Department. 12.2 CERTIFICATION: Consultant personnel preparing the Certified Final Estimate Package shall be CTQP Final Estimates Level II. Duly authorized representative of the Consultant firm will provide a notarized certification on a form pursuant to FDOT's procedures. 12.3 OFFER OF FINAL PAYMENT: Prepare the Offer of Final Payment package as outlined in Chapter 14 of the Review and Administration Manual. The package shall accompany the Certified Final Estimates Package submitted to the Construction Project Manager for review. The Consultant shall be responsible for forwarding the Offer of Final Payment Package to the Contractor. 13.0 AGREEMENT MANAGEMENT: 13.1 GENERAL: With each monthly invoice submittal, the Consultant will provide a Status Report for the Agreement. This report will provide an accounting of the additional Agreement calendar days allowed to date, an estimate of the additional calendar days anticipated to be added to the original schedule time, an estimate of the Agreement completion date, and an estimate of the Consultant funds expiration date per the Agreement schedule for the prime Consultant and Page 10 of 12 Schedule A-Scope of Services (-.vv 168 3 for each subconsultant. The Consultant will provide a printout from the Equal Opportunity Reporting System showing the previous month's payments made to subconsultants. Invoices not including this required information may be rejected. When the Consultant identifies a condition that will require an amendment to the Agreement, the Consultant will communicate this need to the Construction Project Manager for acceptance. Upon acceptance, prepare and submit an Amendment Request (AR), and all accompanying documentation to the Construction Project Manager for approval and further processing. The AR is to be submitted at such time to allow the County 12 weeks to process, approve, and execute the AR. The content and format of the AR and accompanying documentation shall be in accordance with the instructions and format to be provided by the County. The Consultant is responsible for performing follow-up activities to determine the status of each Amendment Request submitted to the County. 13.2 INVOICING INSTRUCTIONS: Monthly invoices shall be submitted to Collier County in a format approved by Collier County, no later than the 20th day of the month following the month being invoiced. If the CONSULTANT cannot submit their monthly invoice on time, the CONSULTANT shall notify Collier County, prior to the due date the reason for the delay and the planned submittal date. Once submitted, the CONSULTANT shall notify the Construction Project Manager via Email of the total delay in calendar days and the reason(s) for the delay(s). All invoices shall be submitted to Collier County in hard copy format. 14.0 OTHER SERVICES: Upon written authorization by the Construction Project Manager, the Consultant will perform additional services in connection with the project not otherwise identified in this Agreement. The following items are not included as part of this Agreement, but may be required by the County to supplement the Consultant services under this Agreement. A. Assist in the timely preparation of all claims and necessary rebuttals with the organization of any and all supporting documentation as needed or required by Collier County pursuant to the Collier County Alternative Dispute Resolution Procedures. B. Provide qualified engineering witnesses and exhibits for any litigation or hearings in connection with the Contract. C. Assist the County Attorney or his designee as directed in the preparation for Binding Arbitration and Pre-Suit Mediation. D. Provide on- and off-site inspection services in addition to those provided for in this Agreement. 14.1 POST CONSTRUCTION CLAIMS REVIEW: In the event the Consultant for the project submits a claim for additional compensation and/or time after the CONSULTANT has completed this Agreement, the CONSULTANT shall, at the written request from Collier County, analyze the claim, prepare a recommendation to the Construction Project Manager covering validity and reasonableness of charges, and/or assist in negotiations leading to settlement of the claim. Compensation will be separately reimbursed by a Supplement to this Agreement. 14.2 CONTRADICTIONS: In the event of a contradiction between the provisions of this Scope of Services and the Consultant's proposal as made a part of their Agreement, the provisions of the Scope of Page 11 of 12 Schedule A-Scope of Services Services shall apply. 1 6 B 3 14.3 COUNTY AUTHORITY The County shall be the final authority in considering modifications to the Construction Contract for time, money or any other consideration except matters agreed to by the Contractor through contract changes negotiated by the Consultant, as authorized in Section 14.0 herein. Page 12of12 Schedule A-Scope of Services } 1683 SCHEDULE B BASIS OF COMPENSATION 1. MONTHLY STATUS REPORTS B.1.1. As a condition precedent to payment, CONSULTANT shall submit to the COUNTY as part of its monthly invoice a progress report reflecting the Project status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1. For the Basic Services provided for in this Agreement, the COUNTY agrees to make the payments to CONSULTANT in accordance with the terms stated below. Payments will be made in accordance with the following Schedule; however, the payment of any particular line item noted below shall not be due until services associated with any such line item have been completed or partially completed to the COUNTY's reasonable satisfaction. Lump sum payments will be made upon the percentage complete. In no event shall such Time and Materials compensation exceed the amounts set forth in the table below. Tasks/Item Description Lump Sum Time and Materials Not-To- Exceed Phased-Task Al Phase I Pre-construction Activities $ $12,168.75 Phase I-Task A2 Phase I CEI Activities $ $422,170.81 Phase I-Task A3 All Phases Post-construction Activities $ $14,536.50 Phase I-Survey Phase I CEI Survey Services $ $8,400.00 Phase I-Lab Testing Phase I Materials Testing Lab Services $ $4,200.00 Phase II-Task A2 Phase II CEI Activities $ $159,856.31 Phase Il-Survey Phase II CEI Survey Services $ $3,600.00 Phase Il-Lab Testing Phase II Materials Testing Lab Services $ $1,800.00 $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ Total Lump Sum Fee $ $ Total Time and Materials Fee $ $626,732.37 GRAND TOTAL FEE $ $626,732.37 Page 19 of 32 PSA Single Project Agreement 2017.010 Ver.l 16B3 B.2.2. U1*Time and Material Fees: The fees noted in Section B.2.1. shall constitute the amounts to be paid to CONSULTANT for the performance of the Basic Services. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT's personnel, with respect to this Project, including all indirect payroll related costs and fringe benefits, all in accordance with and not in excess of the rates set forth in the Attachment 1 to this Schedule B. With each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by the COUNTY, regarding CONSULTANT's Direct Labor Costs incurred at the time of billing, to be reviewed and approved by the COUNTY. There shall be no overtime pay without the COUNTY's prior written approval. B.2.2.1. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has completed such task as of that particular monthly billing. 8.2.3. Cr Lump Sum Fees: The fees noted in Section 2.1. shall constitute the lump sum amount to be paid to CONSULTANT for the performance of the Basic Services. There shall be no B.2.3.1 CONSULTANT shall submit, with each of the monthly status reports provided for under Section B.1.1 of this Schedule B, an invoice for fees earned in the performance of Basic Services and Additional Services during the subject billing month. B.2.4. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided and as set forth in the Amendment authorizing such Additional Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provision of Section 3.4.1 below. There shall be no overtime pay on Additional Services without the COUNTY's prior written approval. B.2.5. The compensation provided for under Section B.2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are due and payable. Page 20 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 3. SCHEDULE OF PAYMENTS B.3.1. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by the COUNTY. B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT's letterhead and must include the Purchase Order Number and Project name and shall not be submitted more than one time monthly. B.3.3. Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. B.3.4. Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for this Agreement or Additional Services, CONSULTANT shall be limited to a maximum markup of five percent (5%) on the fees and expenses associated with such subconsultants and subcontractors. B.3.4.1 Reimbursable Expenses must comply with §112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items: B.3.4.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.4.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by the COUNTY. Such expenses, if approved by the COUNTY, may include coach airfare, standard accommodations and meals, all in accordance with §112.061, Fla. Stat. Further, such expenses, if approved by the COUNTY, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.4.1.3. Permit Fees required by the Project. B.3.4.1.4. Expense of overtime work requiring higher than regular rates approved in advance and in writing by the COUNTY. B.3.4.1.5. Expense of models for the County's use. Page 21 of 32 PSA Single Project Agreement 2017.010 Ver.1 16B3 8.3.4.1.6. Other items on request and approved in writing by the COUNTY. B.3.4.1.7. The CONSULTANT shall bear and pay all overhead and other expenses, except for authorized reimbursable expenses, incurred by CONSULTANT in the performance of the Services. B.3.4.1.8. Records of Reimbursable Expenses shall be kept on a generally recognized accounting basis. B.3.5. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring any reimbursable expenses, and absent such prior approval, no expenses incurred by CONSULTANT will be deemed to be a reimbursable expense. Page 22 of 32 PSA Single Project Agreement 2017 010 Ver.1 1683 SCHEDULE B —ATTACHMENT 1 CONSULTANT'S HOURLY RATE SCHEDULE Title Hourly Rate CEI Senior Project Engineer/Project Manager $172 CEI Project Administrator $123 CEI Contract Support Specialist $90 CEI Senior Inspector/Senior Engineer Intern $93 CEI Inspector/Engineer Intern $70 CEI Landscape Inspector $80 CEI Asphalt Plant Inspector (Highspans) $71 CEI Senior Inspector/Senior Engineer Intern (Premium Overtime)* $17.50 CEI Inspector/Engineer Intern (Premium Overtime)* $12.50 *The overtime rate shall only be used in the event the inspectors work over 40 hours in a given week. The Consultant shall obtain approval from the County's Project Manager in advance of incurring the overtime rate. The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added via an Amendment upon mutual agreement in advance and in writing by the parties. * *Grant Funded: The above hourly rates are for purposes of providing estimate(s), as required by the grantor agency. Page 23 of 32 PSA Single Project Agreement 2017.010 Ver.1 0 1683 SCHEDULE C PROJECT MILESTONE SCHEDULE Cumulative Number of Calendar Days For Completion Task/Item Descriptionfrom Date of Notice to Proceed for Services under this Agreement Phase I - Task Phase I Pre-construction Activities 60 Al Phase 1 - Task Phase I CEI Activities 360 A2 Phase II - Task Phase II CEI Activities 480 A2 Phase I - Task All Phases Post-construction Activities 510 A3 Page 24 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 SCHEDULE D INSURANCE COVERAGE 1. The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the below listed minimum required coverages, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be CONSULTANT's sole responsibility. 2. The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. 3. Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the COUNTY or as specified in this Agreement, whichever is longer. 4. Certificates of insurance acceptable to the COUNTY shall be filed with the COUNTY within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance policies required shall be provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the COUNTY. CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project. 6. The acceptance by the COUNTY of any Certificate of Insurance does not constitute approval or agreement by the COUNTY that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. 7. CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the COUNTY. Page 25 of 32 PSA Single Project Agreement 2017.010 Ver.l 1683 8. Should at any time the CONSULTANT not maintain the insurance coverages required herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand, the COUNTY has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Agreement. 9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and the COUNTY may terminate the Agreement for cause. 10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY. Required by this Agreement? n Yes n No Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability - The coverage must include Employers' Liability with a minimum limit of$ 1,000,000 for each accident. The insurance company shall waive all claims rights against the COUNTY and the policy shall be so endorsed. 1 1. _...•. : e ... e • T._ • •....._ • . . e Se.. .1 e _ A ... a ..._ ..._ .:e where applicable to the completion of the work. Required by this Agreement? fl Yes I I No of-the-work: -W._. ._ e a. Ae I I Yes I I No 13. COMMERCIAL GENERAL LIABILITY. Required by this Agreement? • Yes n No A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Page 26 of 32 PSA Single Project Agreement 2017.010 Ver.1 1663 Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the following: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, $2,000,000 aggregate. B. The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. 14. Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. The insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. Watercraft Liability shall he carried by the CONSULTANT or the _-ee._ _• '.•. _a ....� ,,..'�..� _ e •.:_ _-e..e t...e.• e - •e: • _ A. Required by this Agreement? n Yes ❑ No 16. Aircraft Liability coverage shall, be carried by the CONS-IA-TAW-TAW or the - .► A ► • '..• _ . •.e =-- •..• 11,1010 : _a e__ �• _ _•e __e C _ -e••.a s.. a•. a •.. ,.,,..s... _. -..e.z YesNo •. A e. a._.,•. rte .. e. e _.•._,,. .L a 1a • 17. AUTOMOBILE LIABILITY INSURANCE. Required by this Agreement? n Yes n No Business Auto Liability: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-The ownership. Page 27 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 18. _ , ei _ - . • . a el/ _ __ $, _ . • . •.-_ • , : : n Yes Ti No - _ •_. . e a •_••'_ _ _e• - • _ . ,nce: Coverage shall have minimum limits of $ Per Occurrence. f'YRFR INCIIRAAIC_E - :._ , e • s _.•-t- Yes Ti No S• • . • _ :' _e ..�. r!$. .• 4_ = 55.4•••5_54 .•. . e ':. -C ��.�._ • 20. UMRRE1 I A 1 IARII ITA .o�rr�rv��-c v-v-v�-r-r�-rs-rv..rr�._-rm A. Umbrella Liability may be maintained- as part of the- liability insuracse of t e General Liability, a e A - e••e : :rages required herein an ude--ali coverages- B. The policy shall contain wording to the eff:_ •_ ..* • : e •_. : s- __ _ • underlying limit due to the payment of c4-.••_, • •• ,_ - _ e e , • II• ,e e s , •° • - e s primary-insurance. 21. PROFESSIONAL LIABILITY INSURANCE. Required by this Agreement? IN Yes n No A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its legal liability for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under this insurance. Such insurance shall have limits of not less than $ 1,000,000 each claim and aggregate. B. Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT. Deductible amounts are subject to the approval of the COUNTY. C. The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the COUNTY. D. The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to the COUNTY of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer. In the event Page 28 of 32 PSA Single Project Agreement 2017.010 Ver.1 1683 of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by the COUNTY. 22. VALUABLE PAPERS INSURANCE. In the sole discretion of the COUNTY, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. 23. PROJECT PROFESSIONAL LIABILITY. A. If the COUNTY notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with the COUNTY and the COUNTY's insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT's professional liability policy. If no credit is available from CONSULTANT's current professional policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to the COUNTY. Should no credit accrue to the COUNTY, the COUNTY and CONSULTANT, agree to negotiate in good faith a credit on behalf of the COUNTY for the provision of project-specific professional liability insurance policy in consideration for a reduction in CONSULTANT's self-insured retention and the risk of uninsured or underinsured consultants. B. The CONSULTANT agrees to provide the following information when requested by the COUNTY or the COUNTY's Project Manager: 1. The date the professional liability insurance renews. 2. Current policy limits. 3. Current deductibles/self-insured retention. 4. Current underwriter. 5. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. 6. Cost of professional insurance as a percent of revenue. 7. Affirmation that the design firm will complete a timely project errors and omissions application. C. If the COUNTY elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and the COUNTY will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds. END OF SCHEDULE D Page 29 of 32 PSA Single Project Agreement 2017 010 Ver.! C 1663 This schedule is not applicable. SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida Statutes, AECOM Technical Services, Inc. (company's name) hereby certifies that wages, rates and other factual unit costs supporting the compensation for the services of the CONSULTANT to be provided under the Professional Services A•reement, concerning " CEI Services for Thomasson Drive Beautification Project "project is accurate, complete d current as of the time of contracting. /AdeBY: f / TITLE: % t,I c P✓�1651191 t DATE: i/ 6( 'zc' //"1 • Page 30 of 32 PSA Single Project Agreement 2017.0W Ver.l 1:0 168 3 SCHEDULE F KEY PERSONNEL Name Personnel Category Percentage of Time Crystal Gorman, PE Sr. Project Engineer 10% Floyd Culligan Project Administrator 100% Joe Monahan Sr. Inspector 100% Dominick Walker Inspector 50% Mark Rothenberger Utility Inspector as needed Derek Smith Additional Sr. Inspector as needed Mike O'Leary Additional Sr. Inspector as needed Russell Cooper Additional Inspector as needed Brad Ballinger Additional Inspector as needed Michele Rastelli CSS/Administrative Assistant 20% Nick Myers Landscape Inspector as needed Michael Blevins Asphalt Plant Inspector (Highspans) as needed Charlie Bemis Asphalt Plant Inspector (Highspans) as needed Page 31 of 32 PSA Single Project Agreement 2017.010 Ver.1 1663 SCHEDULE G Other: (Description) ❑ following this page (pages through ) ISI this schedule is not applicable Page 32 of 32 PSA Single Project Agreement 2017.010 Ver.1 „--,.� 16 B 3 A�QDATE(MM/DD/YYYY) CERTIFICATE OF LIABILITY INSURANCE 06/19/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT James Vogel Marsh Risk&Insurance Services CA License#0437153 bac No.Ext): 213-346-5098 FAX No): 212-948-0533 633 W.Fifth Street,Suite 1200 E-MAIL James.l.vogel@marsh.com Los Angeles,CA 90071 ADDRESS: Attn:LosAngeles.CertRequest@Marsh.Com INSURER(S)AFFORDING COVERAGE NAIC# CN101348564-PROJ-GAUE-19-20 09 2025 INSURER A:ACE American Insurance Company 22667 INSURED INSURER B:N/A N/A AECOM AECOM Technical Services,Inc. INSURER c:Illinois Union Insurance Co 27960 4415 Metro Parkway,Suite 404 INSURER D:SEE ACORD 101 Fort Myers,FL 33916 — INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: LOS-002435789-02 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF POLICY EXP LIMITS (MM/DD/YYYY) (MM/DD/YYYY) A X COMMERCIAL GENERAL LIABILITY X HDOG71234137 04/01/2019 04/01/2020 EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR PRS RENTED PREMISES((Ea occurrence) $ 1,000,000 MED EXP(Any one person) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY X PR0. LOC PRODUCTS-COMP/OP AGO $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY ISA H25280532 04/01/2019 04/01/2020 COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ I AUTOS ONLY AUTOS ONLY - (Per accident) _ UMBRELLA LIAB OCCUR EACH OCCURRENCE _ $ — EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ D WORKERS COMPENSATION SEE ACORD 101 04/01/2019 04/01/2020 X PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER Y/N ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ C ARCHITECTS&ENG. EON G21654693 005 04/01/2019 04/01/2020 Per Claim/Agg 1,000,000 PROFESSIONAL LIAB. -CLAIMS MADE” Defense Included DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Re:Project Description:CEI Services for Thomasson Drive Beautification Project.Collier County Project Number:18-7466. Collier County Board of County Commissioners,OR,Board of County Commissioners in Collier County,OR,Collier County Government,OR,Collier County are named as additional insured for GL coverage,but only as respects work performed by or on behalf of the named insured and where required by written contract. Waiver of Subrogation is applicable where required by written contract with respect to WC. This insurance is primary and non-contributory over any existing insurance and limited to liability arising out of the operations of the named insured and where required by written contract with respect to the GL coverage. CERTIFICATE HOLDER CANCELLATION Collier County SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Board of County Commissioners THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 3295 Tamiami Trail E. ACCORDANCE WITH THE POLICY PROVISIONS. Naples,FL 34112 AUTHORIZED REPRESENTATIVE of Marsh Risk&Insurance Services James L.Vogel ©1988-2016 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 1663 AGENCY CUSTOMER ID: ON 101348564 LOC#: Los Angeles A ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY NAMED INSURED Marsh Risk&Insurance Services AECOM AECOM Technical Services,Inc. POLICY NUMBER 4415 Metro Parkway,Suite 404 Fort Myers,FL 33916 CARRIER NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Workers Compensation/Employer Liability cont. Policy Number Insurer States Covered WLR C6589323A Indemnity Insurance Company of North America-NAIC#43575 AOS WLR C65893150 ACE American Insurance Company-NAIC#22667 CA and MA SCF C65893198 ACE American Insurance Company-NAIC#22667 WI Retro WCU C65893393 ACE American Insurance Company-NAIC#22667 OH,Ohio Qualified Self Insured(OSI)-SIR:$500,000;Only applicable to specific qualified entities self-insured in the state of Ohio Severability Of Interest/Cross Liability is included for General Liability coverage. Contractual Liability is included in the General Liability coverage. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD