Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
#17-7117 (Carollo Engineers, Inc)
PROFESSIONAL SERVICES AGREEMENT Contract# 17-7117 for n SCRWTP Reactor Tank Number Four 11 Q CCNA n NON-CCNA THIS AGREEMENT is made and entered into thisday of Srnbk_f 20 by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and Carollo Engineers, Inc. , authorized to do business in the State of Florida, whose business address is 401 North Cattlemen Road, Suite 306,Sarasota,Florida 34232 (hereinafter referred to as the "CONSULTANT" and/or "CONTRACTOR"). WITNESSETH: WHEREAS, the COUNTY desires to obtain the professional services of the CONSULTANT concerning SCRWTP Reactor Tank Number Four (hereinafter referred to as the "Project"), said services being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and; WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows: ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to COUNTY professional services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the COUNTY for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards and other Page 1 of 32 PSA Single Project Agreement 2017.010 Ver.1 governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to the COUNTY. 1.5. CONSULTANT designates Chris Reinbold, P.E. a qualified licensed professional to serve as the CONSULTANT's project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without the COUNTY's prior written approval, and if so removed must be immediately replaced with a person acceptable to the COUNTY. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from the COUNTY to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to the COUNTY. 1.7. The CONSULTANT represents to the COUNTY that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the COUNTY's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Page 2 of 32 PSA Single Project Agreement 2017.010 Ver.1 Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 1.8. In the event of any conflicts in these requirements, the CONSULTANT shall notify the COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY regarding resolution of each such conflict. The COUNTYS approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project. 1.9. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to CONSULTANT's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY reserves the right to make sole determination regarding deductions. After notification of deficiency, if the CONSULANT fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge the Page 3 of 32 PSA Single Project Agreement 2017.010 Ver.) CONSULTANT for services and/or items necessary to correct the deficiencies directly related to the CONSULTANT's non-performance whether or not the COUNTY obtained substitute performance. 1.10. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without the COUNTY's prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt written notice of any such subpoenas. 1.11. As directed by the COUNTY, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real- Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have common naming conventions (i.e. right-of-way- ROW, centerlines- CL, edge-of-pavement- EOP, etc.), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT 2.1. If authorized in writing by the COUNTY through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in the COUNTY's Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by the COUNTY as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. the COUNTY will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If the COUNTY determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to the COUNTY of the emergency within forty-eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT's right it otherwise may have had to seek an adjustment to its compensation or time of performance under this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: Page 4 of 32 PSA Single Project Agreement 2017.010 Ver.1 2.2. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.3. Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, the COUNTY's schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by the COUNTY when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT's control and fault. 2.4. Providing renderings or models for the COUNTY's use. 2.5. Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting the COUNTY in obtaining such process licensing. 2.6. Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.7. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by the COUNTY, other than visits to the Project site or the COUNTY's office. 2.8. Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2.9. Preparing to serve or serving as a CONSULTANT or witness for the COUNTY in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as part of the Basic Services to be provided herein). 2.10. Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice. ARTICLE THREE THE COUNTY'S RESPONSIBILITIES 3.1. The COUNTY shall designate in writing a project manager to act as the COUNTY's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define the COUNTY's policies and decisions with respect to CONSULTANT's services for the Project. However, the Project Manager is not authorized to issue any verbal or written orders or instructions to the CONSULTANT that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: Page 5 of 32 PSA Single Project Agreement 2017 010 Vei 1'`a a. The scope of services to be provided and performed by the CONSULTANT hereunder; b. The time the CONSULTANT is obligated to commence and complete all such services; or c. The amount of compensation the COUNTY is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: a. Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; b. Provide all criteria and information requested by CONSULTANT as to the COUNTY 's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; c. Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT's disposal all available information in the COUNTY's possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; d. Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the COUNTY with respect to the services to be rendered by CONSULTANT hereunder. ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from the COUNTY for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT's services from any cause whatsoever, including those for which the COUNTY may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from the COUNTY. CONSULTANT's sole remedy against the COUNTY will be the right to seek an extension of time Page 6 of 32 PSA Single Project Agreement 2017.010 Ver.l to its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT's compensation shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the COUNTY's satisfaction that the CONSULTANT's performance is or will shortly be back on schedule. 4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by the COUNTY to CONSULTANT be deemed a waiver of any right or claim the COUNTY may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the COUNTY for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction of the COUNTY's Project Manager before payment for the fixed price contract is authorized. - _.•• •- _.:• •a e • - • - - - • �,. _. _•• ', � • �,.. q_._ .. �� e.. ••„ '_.....,, :. > ••J a o.---Z�.�•. „ „.�d • •-,.... a -e �--� .e_ D ,,. e _.e.• .. a as ,-e ••w_•e e e •e eta : e •_ •a �.• - .a,. - - as - • - - • • - e •.- a. . • : •. _ e _ : e • • •.a..�_.... u• .�•• y_.•. _ ,..,• •l!a r • : e. � _ •_;� •: .: _e-'- z .. - ....teee e • W _._.,, • v _em a .. a _-_e_ • _.._„_e : • ,,....•• e=_. .e • e . ee • e • e •e_ e_•_ ��e. a • e •• e -- e _ _. - i� •• - e_. _ -,._ a- e-.. .. _ e-..,et� .,•-..-e _�a� ..-,,..�. e-..{�-ems prOlp a -�--• _ `•--` 5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above. [1 • • t e : • - . e_ _ - - e • • . . `e=a to • - -• =e - .. Page 7 of 32 PSA Single Project Agreement 2017 010 Ver 1 . .-. .- - . e e e - e e e 'e •e - ' -. e .- e . e y ARTICLE SIX THE OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by the COUNTY, CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement("Project Documents"). The COUNTY shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to the COUNTY the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring the COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use on this Project. CONSULTANT warrants to the COUNTY that it has full right and authority to grant this license to the COUNTY. Further, CONSULTANT consents to the COUNTY's use of the Project Documents to complete the Project following CONSULTANT's termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges the COUNTY may be making Project Documents available for review and information to various third parties and hereby consents to such use by the COUNTY. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder. The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall defend, indemnify and hold harmless the COUNTY, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce Page 8 of 32 PSA Single Project Agreement 2017.010 Ver.1 any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 8.1.1. The duty to defend under this Article 8 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the CONSULTANT, the COUNTY and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to CONSULTANT. The CONSULTANT's obligation to indemnify and defend under this Article 8 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the COUNTY or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2. All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3. All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests' provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against the COUNTY for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by the COUNTY applicable to this Project. 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. Page 9 of 32 PSA Single Project Agreement 2017.010 Ver.1 9.4. CONSULTANT, its subconsultants and the COUNTY shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by the COUNTY, except such rights as they may have to the proceeds of such insurance held by any of them. 9.5. All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements: 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff, unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this Agreement shall, however, be construed as constituting an agreement between the COUNTY and any such other person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third party any claim or right of action against the COUNTY beyond such as may then otherwise exist without regard to this Agreement. 10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. All personnel, identified in Schedule F shall not be removed or replaced without the COUNTY's prior written consent. 10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the COUNTY. Each subconsultant or subcontract agreement shall preserve and protect the rights of the COUNTY under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the sub consulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub- subconsultants or sub-subcontractors. 10.4. CONSULTANT acknowledges and agrees that the COUNTY is a third-party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between the COUNTY and any subconsultant or subcontractor. Further, all such contracts shall Page 10 of 32 PSA Single Project Agreement 2017 010 Vera provide that, at the COUNTY's discretion, they are assignable to the COUNTY upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS 11.1. CONSULTANT's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the COUNTY arising out of this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANT's services nor payment by the COUNTY shall be deemed to be a waiver of any of the COUNTY's rights against CONSULTANT. ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for the COUNTY to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT's failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT's failure to properly and timely perform the services to be provided hereunder or as directed by the COUNTY, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT's principals, officers or directors, or (d) CONSULTANT's failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT's failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The COUNTY may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below. 12.3. The COUNTY shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such termination for convenience, CONSULTANT'S recovery against the COUNTY shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against the COUNTY, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. Page 11 of 32 PSA Single Project Agreement 2017.010 Ver.1 12.4. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the COUNTY all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Article 6, that are in CONSULTANT's possession or under its control. 12.5. The COUNTY shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT'S sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 12.6. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) the COUNTY otherwise persistently fails to fulfill some material obligation owed by the COUNTY to CONSULTANT under this Agreement, and (ii) the COUNTY has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving THE COUNTY a second fourteen (14) days written notice of CONSULTANT'S intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to the COUNTY of CONSULTANT's intent to terminate this Agreement. If the COUNTY does not cure its default within fourteen (14) days after receipt of CONSULTANT'S written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the COUNTY, terminate the Agreement and recover from the COUNTY payment for Services performed through the termination date, but in no event, shall CONSULTANT be entitled to payment for Services not performed or any other damages from the COUNTY. ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. 13.2. [U CCNA Projects: In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs supporting the compensation for CONSULTANT'S services to be provided under this Agreement are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees that the original Agreement price and any additions thereto shall be adjusted to exclude any significant sums by which the COUNTY determines the Agreement price was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit costs. All such adjustments shall be made within one (1)year following the end of this Agreement. Page 12 of 32 PSA Single Project Agreement 2017 010 Ver.l ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following the COUNTY's address of record: Board of County Commissioners for Collier County, Florida Division Director: Tom Chmelik Division Name: PUD Engineering & Project Management Address: 3339 Tamiami Trail East, Suite 303 Naples, Florida 34112 Administrative Agent/PM: Alicia Abbott, Project Manager Telephone: 239-252-5344 E-Mail(s): alicia.abbott@colliercountyfl.gov 16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT'S address of record: Company Name: Carollo Engineers, Inc. Address: 401 North Cattlemen Road, Suite 306 Sarasota, Florida 34232 Authorized Agent: Bob Cushing, Ph.D., P.E. Attention Name & Title: Chris Reinbold, P.E. Telephone: 561-868-6407 E-Mail(s): creinbold@carollo.com Page 13 of 32 PSA Single Project Agreement 2017.010 Ver 1 16.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. ARTICLE SEVENTEEN MISCELLANEOUS 17.1. CONSULTANT, in representing the COUNTY, shall promote the best interests of the COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair dealing. 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of the COUNTY. 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 17.8. This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 17.9. The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE II Schedule E CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE Schedule F KEY PERSONNEL Schedule G Other: Solicitation # 17-7117 , including all Attachment(s), Exhibit(s) &Addendum Consultant's Proposal Page 14 of 32 PSA Single Project Agreement 2017.010 Ver.1 17.10. 11 _• • . . - . . .- - e• --. . ••eae •: : .•_ • • •:. _e• •. ••-■ •• • •- ► '_ ea. e _ ee • :• - - _ _••••_ a •: .• . ..•- ie --•..c.a -a-. _ e :_:_•-.a_: .. - •- c a._ e _ e •- a• n U-• _�.. •._ -...•• e • •• -u-• •. _ ••• •• • e :_: : ..: - •- Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved e.. _.a e. a•. , •- _._ e e •: A.e. -_u:•. a: _e• • e: __e. a ...•e_..•. ._ •aa. : _ e _e_ ee.e... .••• _ met a: e• _ !e ••-• - -•e. s- _ _ -_ _ ► _ • _ A _ ► - -- : •• 17.11. Applicability. Sections corresponding to any checked box (II ) expressly apply to the terms of this Agreement. ARTICLE EIGHTEEN APPLICABLE LAW 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE NINETEEN SECURING AGREEMENT/PUBLIC ENTITY CRIMES 19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. ■ At the time this Agreement is executed, CONSULTANT shall sign and deliver to the COUNTY the Truth-In-Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E. CONSULTANT's compensation shall be adjusted to exclude any sums by which the COUNTY determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity, may not be Page 15 of 32 PSA Single Project Agreement 2017 010 Vert awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." ARTICLE TWENTY DISPUTE RESOLUTION 20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached during negotiations to the COUNTY for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached at mediation to the COUNTY's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 20.2. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE TWENTY ONE IMMIGRATION LAW COMPLIANCE 21.1. By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the COUNTY shall have the discretion to unilaterally terminate this Agreement immediately. (signature page to follow) Page 16 of 32 PSA Single Project Agreement 2017.010 VST..l IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement the day and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS FOR COLLIER COU , FLORIDA, Crystal K. Kinzel, Clerk & Comptr ler Ct. Date: a � By. Chairman Attest as to Chairman's Andy Solis, Esq. signature only. Ape = ed as to or and Legality: Aria VIM County Attorney 7:e-a Name Consultant: Consultant's Witnesses: Carollo Engineers, Inc. V/1(c'tt I By: frit Witness VisCe o.5,c<•11— V `e� vie Uhc 2 (✓eS Name and Title Pl;ti'PoAr Name and Title \YckCi–d-et Witn: I it, a ry) Name and Title Page 17 of 32 PSA Single Project Agreement 2017.010 Ver.1 SCHEDULE A SCOPE OF SERVICES • following this page (pages through 6 ) Page 18 of 32 PSA Single Project Agreement 2017.010 Ver.1 South County Regional Water Treatment Plant Reactor Tank#4 Scope of Services Task I: Technical Memorandum 1: Consultant is to prepare a draft technical memorandum with an evaluation of the existing lime softening treatment system, and the and 2005 design documents by Hazen & Sawyer. The draft memorandum will identify if there are any other cost effective softening system treatment schemes and discuss advantages and disadvantages of identified treatment schemes, along with recommended improvements. Evaluations will consist of capital cost, present worth, operation and maintenance costs and functional analyses, as applicable. The evaluation will include the lime softening reactor/clarifier; lime storage, slaking, feed; and sludge wasting. The evaluation should be used to establish the basis of design of the components indicated in Task II that will be incorporated into the project. Recommendations may be made for items which will not be incorporated into the project for the COUNTY's use. (Items not specifically included in Task II will be addressed in future projects.) In-House QA/QC Reviews The draft technical memorandum will receive a CONSULTANT in-house QA/QC review prior to submittal to COUNTY. These reviews will consist of comments from senior level staff members and identify document compliance with applicable codes and standards. Review with Owner The draft technical memorandum will be distributed to COUNTY (eight copies) in hard copy, MSWord format and PDF format, approximately two weeks prior to the scheduling of a review meeting. This review meeting will serve as a forum for receiving and reviewing COUNTY input. It is anticipated that the technical memorandum will require one review meeting/workshop. Finalize Technical Memorandum Based on comments received from COUNTY, CONSULTANT will finalize the technical memorandum. Eight copies in hard copy, MSWord format and PDF format of each will be forwarded to OWNER for final acceptance. Task II: Prepare Basis of Design Report: CONSULTANT is to prepare a Basis of Design report presenting a narrative of the proposed work, preliminary construction drawings(60%level),design criteria, preliminary estimate of construction costs, a preliminary project schedule, major equipment specifications, drawings, and consultants' recommendation for proceeding with detailed design. The report should include (but not be limited to) soil borings, subsurface explorations, and any other similar investigations necessary for establishing a baseline from which to proceed with the final design of the project. It is anticipated that the Basis of Design report will contain the level of design detail which will support completing the identified permit applications and submission to the applicable agencies. The Basis of Design Report is to include each of the following topics: 7lPage 1. Civil/Site Work/Paving, Grading and Drainage, and Yard Piping 2. Hydraulic Profile 3. Reclaimed Water Pumping/Transmission (and Reject Water Handling) 4. Electrical Systems 5. Control and Information Systems 6. Probable Opinion of Construction and Operation and Maintenance Cost 7. Construction Sequencing and Probable Construction Schedule The systems and facilities to be included in this effort are as follows: 1. Lime softening reactor/clarifier 2. Yard piping connections (influent raw water, effluent softened water, potable water for sparge ring and hydraulic valve actuation, sludge blowdown, and basin overflow) 3. Platform connection from new reactor/clarifier No. 4 to existing reactor/clarifier No. 3 4. PLC programming to interface the controls for reactor/clarifier No. 4 into the plant control system In-House QA/QC Reviews The Basis of Design Report will receive a CONSULTANT in-house QA/QC review prior to submittal to COUNTY. These reviews will consist of comments from senior level staff members and identify document compliance with applicable codes and standards. Review with Owner Approximately two weeks after delivery of the draft Basis of Design report to COUNTY, CONSULTANT will schedule one meeting with COUNTY to review and incorporate comments. Consultant will prepare and provide meeting minutes for all design review meetings within three (3) business days. Finalize Basis of Design Report Based on comments received from COUNTY, CONSULTANT will finalize the Basis of Design Report. Eight copies in hard copy, MSWord format and PDF format of each will be forwarded to OWNER for final acceptance. Hardcopy drawings shall either be provided as figures within the report, or if bound separately, as half size drawings (11" x 17"), and two sets full size drawings. Task III: Final Design Preparation of Proposed Final Documents Based on input received from COUNTY at review meetings during the preliminary design phase and associated design reviews CONSULTANT will prepare final(90 percent)contract documents. Project Peer Review CONSULTANT will conduct a 90 percent completion stage project peer review to provide QA/QC of the final contract documents and cost estimate prior to submittal to COUNTY. The review will include final interdisciplinary checks, general coordination, MANPRINT, and constructability issues, and will be conducted by senior level personnel (internal Technical Review Committee) not involved in the day-to-day activities of the project to ensure a "fresh eyes" review. 21Page Delivery of Proposed Final Documents CONSULTANT will furnish COUNTY with eight (8) hard copies, electronic copies in Microsoft schedule and PDF format, the proposed final contract documents and the 90 percent completion level detailed opinion of probable construction cost. Hardcopy drawings shall be provided as half size drawings (11"x 17"), and two full set drawings. Review and Revisions to the Proposed Final Contract Documents Approximately two(2)weeks after delivery of the proposed final contract documents to COUNTY, CONSULTANT will schedule a review meeting with COUNTY, so that any final changes that may be necessary to meet the project's budgetary requirements can be incorporated. Acceptance of Final Contract Documents Electronic copies of the final documents (incorporating all requested changes) will be submitted to the County for final acceptance. Once final acceptance is received, one master set of originals and electronic copies in MSWord format, electronically on AutoCAD disks (current COUNTY version), and PDF format of the final (100% complete) contract documents, will be forwarded to COUNTY. Hardcopy drawings shall be provided as half size drawings (11" x 17"). Signed and sealed documents for the COUNTY's use will be provided with certified digital signatures meeting the requirements of 61G15-23.003 and 61G15-23.004, F.A.C. Task IV: Additional Services Surveying Site surveying by a qualified Florida-licensed surveyor of the treatment facility area will be performed to establish baseline conditions for the Design Report and serve as control of hydraulic points and miscellaneous items during construction. Laboratory Testing and Geotechnical Services Laboratory testing and geotechnical work associated with the characterization of soils for structural design and laboratory testing of materials during construction. Task V: Permitting Services CONSULTANT will prepare and submit construction permit applications pertaining to the SCRWTP project. The scope of this project includes the following: 1. Florida Department of Environmental Protection (FDEP) Environmental Resource Permit and the FDEP Permit to Construct. 2. Collier County Growth Management Division Site Development Plan Amendment, if applicable. 3. Initial application for South Florida Water Management District (SFWMD) Environmental Resource Permit (including stormwater management system update). 4. Provide the necessary documents for the contractor to submit for Collier County Growth Management building permits. 5. COUNTY will pay all permit fees. 31Page Prepare up to two (2) written responses to the regulatory agencies request for additional information (RAI) regarding each permit application. Task VI: Construction Bid Services 1. COUNTY Procurement staff will administer the biding process. 2. CONSULTANT shall assist COUNTY in securing bid and: a. Provide interpretation and clarification of Contract Documents during bidding; b. Attend pre-bid meeting with prospective bidders; c. Assist COUNTY in evaluating bids or proposals and in assembling and awarding contracts for construction, materials, equipment and services; d. Assist COUNTY in evaluating bidder's previous experience, if necessary; 3. Prepare and issue addenda as appropriate to interpret or clarify contract documents. 4. Provide COUNTY with a recommendation to make a contract award, as necessary. 5. In the case that construction bids exceed the final CONSULTANT'S estimate of probable construction cost by more than fifteen (15) percent, CONSULTANT will, at its expense, analyze the cause or causes of the overrun and provide suggestions to correct the same. Task VII: Construction Contract Administration Pre-construction Conference and Progress Meetings Consult with COUNTY and Contractors as reasonably required and necessary with regard to construction of the Project. Consultation will include attendance at the pre-construction conference and monthly coordination meetings with COUNTY, the CEI Representative, and the Contractor. Contract Interpretation and Clarifications Issue interpretations and clarifications of Contract Documents during construction, and evaluate requests for substitutions or deviations from the Contract Documents. Notify COUNTY of any such requested deviations or substitutions and when reasonably necessary, provide COUNTY with a recommendation concerning same. Shop Drawings/Submittals Review shop drawings, diagrams, illustrations, catalog data, schedules and samples, the results of laboratory tests and inspections, and other data that Contractors are required to submit for conformance with the design concept of the Project and compliance with the provisions of the Contract Documents. Record Drawings Prepare and submit to COUNTY upon completion of construction of Project, one set of digitally signed and sealed record drawings and electronically on AutoCAD disks (current COUNTY version), including those changes made during the construction process, using information supplied by the Contractors and other data which can reasonably be verified by CONSULTANT's personnel. Construction engineering and inspection (CEI) services will be provided to the COUNTY by others under a separate Work Order or County Inspection Staff. It is assumed that the CEI firm will review contractor mark- ups to the contract documents on a monthly basis 4IPag throughout the construction period. It is further assumed that the Contractor will provide as-built contract documents to the CONSULTANT for use in preparing reproducible and electronic record drawings. Post Design and Services during Construction The CONSULTANT is expected to provide an experienced, competent engineer(s) for the types of work in this section of the project. The following activities outline the post design and services during construction to be provided during the construction and project close-out phase of the project: a. Schedule and attend all progress meetings and conferences with the County and contractors biweekly for the construction period. Prepare agenda and distribute minutes from previous meeting. Prepare meeting minutes for pre-construction and progress meetings. Coordinate all subsequent start up, design resolution, differing field conditions, and punch list walk through meetings. Prepare a list of issues needing resolution after each meeting and ensure that they are fulfilled. b. Review and evaluate the proposed construction schedule and the schedule of values used for progress payment purposes. Provide input and recommendations to the Public Utilities project manager and operations staff. c. Coordinate all construction and design issues with the Owner, CEI, and contractor as directed by the Owner. d. Provide timely review, recommendations and approval of shop drawings, submittal information and 0 & M Manuals. e. Respond to Requests for Information from the contractor within three working days for items marked critical and five working days for all other items. Coordinate requests with Public Utilities project manager and operational staff at SCRWTP. f. Provide construction contract administration consisting of: i. Review and approval of payment applications, ii. Review of construction schedule updates and field progress, iii. Review of change order requests and preparation of work directives and change orders, iv. Review record drawings for completeness and accuracy on a daily basis. v. Review and approve final O&M manuals provided by the contractor. vi. Review document prepared by Contractor with a summary of the operations Plan for conformance to the Contract Documents considering current operational conditions at the proposed time of startup. vii. Certify project/contract completion. viii. Attend start-ups. ix. Coordinate training to plant personnel which will be provided by the respective equipment manufacturers and Contractor. x. Prepare, sign, and seal final record drawings. xi. Certify to FDEP that the project and permit conditions have completed in substantial conformance to the Contract Documents and any approved revisions thereof. g. Provide operational coordination to assist the County to maintain continuous compliance with FDEP requirements and to maintain production of irrigation quality (IQ)water. h. Conduct periodic site observation of construction to achieve the tasks and scope of work, and provide trip reports with photographs to the County via electronic E-mails. Daily inspection services will be provided by the COUNTY. COUNTY shall provide inspection reports to CONSULTANT for review, as appropriate. CONSULTANT will provide specialty inspections based on an agreed upon frequency at key times during the construction process. 51Page i. Provide engineering professional(s)experienced in water treatment systems to perform the tasks in this RFP and to professionally respond to questions. j. Attend project meetings in order to monitor progress, respond to field issues, communicate with the contractor, and coordinate communications with the contractor and Public Utilities project manager and operational staff at SCRWTP which will be schedule to occur bi-weekly during the construction period. k. Coordinate with Owner and contractor during the transition period upon commencement of responsibilities for these services. Operations &Maintenance Manual CONSULTANT will review Operation&Maintenance manuals, and will provide approve or provide comments. The consultant will assist with the coordination of the contractor training activities as identified within the Contract Documents. Process Startup Assistance Provide one personnel experienced in plant startups to oversee the startup activities of the new facilities on an as-needed basis. The responsibilities of the startup personnel may include: 1. Review of Contractor's cleaning, testing, and startup procedures. 2. Review and approval of Contractor's component and system tests. 3. Coordinate initial operations with COUNTY and the CEI. 4. Recommend to the COUNTY the acceptance of equipment and/or systems. 5. Recommend and establish operating procedures for all systems and process. 6. Review, observe and accept startup procedures to verify that proposed protocol is in conformance with the intent of the Contract Documents. 7. Assist COUNTY in data collection and trending during and following startup for process control and completion of monthly operating reports during the specified commissioning period. Operations Support CONSULTANT is expected to provide technical support to COUNTY, which is anticipated to include contingency planning, flow management and seasonal readiness to develop the work restrictions to be incorporated into the Contract Documents for the COUNTY to meet water production and distribution needs during the construction period. CONSULTANT will then review Contractor's plans for construction for conformance to the Contract Documents during the construction and start-up and commissioning phases,which may occur through all seasons(high demand season). slPag SCHEDULE B BASIS OF COMPENSATION 1. MONTHLY STATUS REPORTS B.1.1. As a condition precedent to payment, CONSULTANT shall submit to the COUNTY as part of its monthly invoice a progress report reflecting the Project status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1. For the Basic Services provided for in this Agreement, the COUNTY agrees to make the payments to CONSULTANT in accordance with the terms stated below. Payments will be made in accordance with the following Schedule; however, the payment of any particular line item noted below shall not be due until services associated with any such line item have been completed or partially completed to the COUNTY's reasonable satisfaction. Lump sum payments will be made upon the percentage complete. In no event shall such Time and Materials compensation exceed the amounts set forth in the table below. Tasks/Item Description Lump Sum Time and Materials Not-To- Exceed 1 Technical Memorandum 1 $26,267 $ 2 Prepare Basis of Design Report $74,691 $ 3 Final Design $68,511 $ 4 Additional Services $15,000 $ 5 Permitting $13,930 $ 6 Construction Bid Services $6,787 $ 7 Construction Contract Administration $130,473 $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ Total Lump Sum Fee $335,659 $ Total Time and Materials Fee $ $ GRAND TOTAL FEE $335,659 $ Page 19 of 32 PSA Single Project Agreement 2017.010 Ver.1 B.2.2. ❑*Time and Material Fees: The fees noted in Section B.2.1. shall constitute the amounts to be paid to CONSULTANT for the performance of the Basic Services. Direct Labor Costs mean •.e e:_ • e tam.. •• ... . -. , . • • . ' •- _e••:: with r:_,:_ e .'_ r ._ _.', - ., :_ e_ e - •• .•,e benefits, all in aa - ,.... • •• •. •.. - _t__ • •- - - aa .. 'a •_ _ _•.••t• , • __ate . With each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by the COUNTY, regarding CONSULTANT's Direct Labor Costs incurred at the time of billing, to be reviewed and approved by the COUNTY. There shall be no overtime pay without the COUNTY's prior written approval. B.2.2.1. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has completed such task as of that particular monthly billing. B.2.3. 1* Lump Sum Fees: The fees noted in Section 2.1. shall constitute the lump sum amount to be paid to CONSULTANT for the performance of the Basic Services. There shall be no overtime pay without the COUNTY's prior written approval. B.2.3.1 CONSULTANT shall submit, with each of the monthly status reports provided for under Section B.1.1 of this Schedule B, an invoice for fees earned in the performance of Basic Services and Additional Services during the subject billing month. B.2.4. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided and as set forth in the Amendment authorizing such Additional Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provision of Section 3.4.1 below. There shall be no overtime pay on Additional Services without the COUNTY's prior written approval. B.2.5. The compensation provided for under Section B.2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are due and payable. Page 20 of 32 PSA Single Project Agreement 2017.010 Ver.1 3. SCHEDULE OF PAYMENTS B.3.1. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by the COUNTY. B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT's letterhead and must include the Purchase Order Number and Project name and shall not be submitted more than one time monthly. B.3.3. Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. B.3.4. Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for this Agreement or Additional Services, CONSULTANT shall be limited to a maximum markup of five percent (5%) on the fees and expenses associated with such subconsultants and subcontractors. B.3.4.1 Reimbursable Expenses must comply with §112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items: B.3.4.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.4.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by the COUNTY. Such expenses, if approved by the COUNTY, may include coach airfare, standard accommodations and meals, all in accordance with §112.061, Fla. Stat. Further, such expenses, if approved by the COUNTY, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.4.1.3. Permit Fees required by the Project. B.3.4.1.4. Expense of overtime work requiring higher than regular rates approved in advance and in writing by the COUNTY. B.3.4.1.5. Expense of models for the County's use. Page 21 of 32 PSA Single Project Agreement 2017.010 Ver.1 B.3.4.1.6. Other items on request and approved in writing by the COUNTY. B.3.4.1.7. The CONSULTANT shall bear and pay all overhead and other expenses, except for authorized reimbursable expenses, incurred by CONSULTANT in the performance of the Services. B.3.4.1.8. Records of Reimbursable Expenses shall be kept on a generally recognized accounting basis. B.3.5. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring any reimbursable expenses, and absent such prior approval, no expenses incurred by CONSULTANT will be deemed to be a reimbursable expense. Page 22 of 32 PSA Single Project Agreement 2017.010 Ver.1 SCHEDULE B —ATTACHMENT 1 CONSULTANT'S HOURLY RATE SCHEDULE Title Hourly Rate The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added via an Amendment upon mutual agreement in advance and in writing by the parties. ❑ .A. - - A. A .. A A. A •A•.A .. - -. t.A. A. .- . _• . Page 23 of 32 PSA Single Project Agreement 2017.010 Ver.1 SCHEDULE C PROJECT MILESTONE SCHEDULE Cumulative Number of Calendar Days Task/Item For Completion Description from Date of Notice to Proceed for Services under this Agreement 1 Technical Memorandum 850 2 Preliminary Design Report 850 3 Final Design Services 850 4 Additional Services 850 5 Permitting 850 6 Bidding Services 850 7 Construction Contract Administration 850 Page 24 of 32 PSA Single Project Agreement 2017.010 Ver.1 SCHEDULE D INSURANCE COVERAGE 1. The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the below listed minimum required coverages, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be CONSULTANT's sole responsibility. 2. The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. 3. Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the COUNTY or as specified in this Agreement, whichever is longer. 4. Certificates of insurance acceptable to the COUNTY shall be filed with the COUNTY within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance policies required shall be provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the COUNTY. CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project. 6. The acceptance by the COUNTY of any Certificate of Insurance does not constitute approval or agreement by the COUNTY that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. 7. CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the COUNTY. Page 25 of 32 PSA Single Project Agreement 2017.010 Ver.1 8. Should at any time the CONSULTANT not maintain the insurance coverages required herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand, the COUNTY has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Agreement. 9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and the COUNTY may terminate the Agreement for cause. 10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY. Required by this Agreement? 1111Yes No Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability - The coverage must include Employers' Liability with a minimum limit of$ 100,000 for each accident. The insurance company shall waive all claims rights against the COUNTY and the policy shall be so endorsed. 11. United States Longshoreman's and Harbor Worker's Act coverage shall be maintained where applicable to the completion of the work. Required by this Agreement? I 1 Yes ■ No 12. Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Required by this Agreement? Yes 1.1 No 13. COMMERCIAL GENERAL LIABILITY. Required by this Agreement? • Yes 1 1 No A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Page 26 of 32 PSA Single Project Agreement 2017.010 Ver.1 Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the following: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, $2,000,000 aggregate. B. The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. 14. Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. The insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 15. Watercraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in subparagraph (1) above if applicable to the completion of the Services under this Agreement. Required by this Agreement? ❑ Yes n No 16. Aircraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Required by this Agreement? Ti Yes IN No 17. AUTOMOBILE LIABILITY INSURANCE. Required by this Agreement? n Yes ❑ No Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-The ownership. Page 27 of 32 PSA Single Project Agreement 2017.010 Ver.1 18. TECHNOLOGY ERRORS AND OMISSIONS INSURANCE. Required by this Agreement? • Yes ❑ No Technology Errors and Omissions Insurance: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence. 19. CYBER INSURANCE. Required by this Agreement? 0 Yes ❑ No Cyber Insurance: Coverage shall have minimum limits of$ 1,000,000 Per Occurrence. 20. UMBRELLA LIABILITY. A. Umbrella Liability may be maintained as part of the liability insurance of the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverages required herein and shall include all coverages on a "following form" basis. B. The policy shall contain wording to the effect that, in the event of the exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. 21. PROFESSIONAL LIABILITY INSURANCE. Required by this Agreement? n Yes ❑ No A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its legal liability for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under this insurance. Such insurance shall have limits of not less than $1,000,000 each claim and aggregate. B. Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT. Deductible amounts are subject to the approval of the COUNTY. C. The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the COUNTY. D. The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to the COUNTY of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer. In the event Page 28 of 32 PSA Single Project Agreement 2017.010 Ver.1 of more than a twenty percent(20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by the COUNTY. 22. VALUABLE PAPERS INSURANCE. In the sole discretion of the COUNTY, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. 23. PROJECT PROFESSIONAL LIABILITY. A. If the COUNTY notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with the COUNTY and the COUNTY's insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT's professional liability policy. If no credit is available from CONSULTANT's current professional policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to the COUNTY. Should no credit accrue to the COUNTY, the COUNTY and CONSULTANT, agree to negotiate in good faith a credit on behalf of the COUNTY for the provision of project-specific professional liability insurance policy in consideration for a reduction in CONSULTANT's self-insured retention and the risk of uninsured or underinsured consultants. B. The CONSULTANT agrees to provide the following information when requested by the COUNTY or the COUNTY's Project Manager: 1. The date the professional liability insurance renews. 2. Current policy limits. 3. Current deductibles/self-insured retention. 4. Current underwriter. 5. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. 6. Cost of professional insurance as a percent of revenue. 7. Affirmation that the design firm will complete a timely project errors and omissions application. C. If the COUNTY elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and the COUNTY will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds. END OF SCHEDULE D Page 29 of 32 07-3 PSA Single Project Agreement 2017.010 Ver.1>` _.• ❑ This schedule is not applicable. SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida Statutes, Carollo Engineers, Inc. (company's name) hereby certifies that wages, rates and other factual unit costs supporting the compensation for the services of the CONSULTANT to be provided under the Professional Services Agreement, concerning " 17-7117-SCRWTP Reactor Tank Number Four "project is accurate, complete and current as of the time of contracting. BY: TITLE: VIZ e ei(e‘Side v DATE: / PV Page 30 of 32 PSA Single Project Agreement 2017.010 Ver.1 SCHEDULE F KEY PERSONNEL Name Personnel Category Percentage of Time Tyler Smith Engineer 12 Janice Mudd Clerical/Admin 8 Christopher Reinbold Senior Engineer 7 Andrea Carpenter Engineer 10 Mark Ludwigson Engineer 8 Douglass Perry Designer 8 Joseph Hanlon Senior Engineer 7 Arsalan Akram Senior Engineer 5 Rich Warner Senior Engineer 5 Lyle Munce Senior Project Manager 3 Vincent Hart Senior Engineer 3 James Keistler Senior Designer 3 Robert Cushing Principle 1 Page 31 of 32 PSA Single Project Agreement 2017 010 Ver.1 SCHEDULE G Other: (Description) I following this page (pages through ) ❑■ this schedule is not applicable Page 32 of 32 PSA Single Project Agreement 2017 010 Ver 1 AC 7 CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) `------- 8/16/2018 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Risk Strategies Company CONTACT 2040 Main Street, Suite 450 PHONE Risk Strategies Company FAX Irvine, CA 92614 (A/C.No.Ext): E-MAIL 949-242-9240 (A/C,No): ADDRESS: syounq@risk-strateqies.com INSURER(S)AFFORDING COVERAGE NAIC# www.risk-strategies.com CA DOI License No.OF06675 INSURER A: Continental Insurance Company 35289 INSURED INSURER B: American Casualty Company of Reading,PA 20427 Carollo Engineers, Inc. 2700 Ygnacio Valley Road, #300 INSURER c: Valley Forge Insurance Company 20508 Walnut CCreek CA 94598 INSURERD: Continental Casualty Company 20443 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 43680840 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL sPOLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD wVD POLICY NUMBER LIMITS (MM/DD/YYYY) IMM/DD/YYYY) A `/ COMMERCIAL GENERAL LIABILITY ✓ 6050490317 12/31/2017 12/31/2018 EACH OCCURRENCE $$1,000,000 DAMAGE CLAIMS-MADE ,/ OCCUR PREM SESO(Ea occurrence) $$1,000,000 ✓ Deductible$0 MED EXP(Any one person) $$25,000 PERSONAL&ADV INJURY $$1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $$2,000,000 POLICY ✓ Tpa, LOC PRODUCTS-COMP/OP AGG $$2,000,000 OTHER: $ A AUTOMOBILE LIABILITY 6050490267 12/31/2017 12/31/2018 COMBINED tSINGLE LIMIT $$1,000,000 ✓ ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ ✓ AUTOS ONLY ✓ AUTOS ONLY (Per accident) Ded:Comp/Collision $$1,000 UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ B WORKERS COMPENSATION ✓ 6050490270 12/31/2017 12/31/2018 / STATUTE I KH Deductible:$0 C AND EMPLOYERS'LIABILITY Y/N 6050490298 12/31/2017 12/31/2018 ANYPR PRIE O /PARTN R/E ECUTIVE N N/A E.L.EACH ACCIDENT $$1,000,000 OFFICE(Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $$1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $$1,000,000 D Professional Liability AEH288354410 7/4/2018 7/4/2019 Each Claim: $1,000,000 Unlimited Prior Acts Aggregate: $1,000,000 Deductible: $400,000 DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Projects as on file with the insured including but not limited to:For any and all work performed on behalf of Collier County,including Contract#17-7117 for SCRWTP Reactor Tank Number Four.Carollo project#not yet assigned.Collier County Board of County Commissioners is included as additional insured with respect to general liability.All insurance is on a primary and non-contributory basis if and to the extent required by written contract.Waiver of subrogation included with respect to workers'compensation. CERTIFICATE HOLDER CANCELLATION Collier CountyBoard of CountyCommissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 3295 Tamiami Trail E. ACCORDANCE WITH THE POLICY PROVISIONS. Naples FL 34112 AUTHORIZED REPRESENTATIVE K‘V:/� C I Michael Christian ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 43680840 1 *17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks 18/16/2018 3:20:05 PM (PDT) 1 Page 1 of 8 AccP CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DDIYYYY) �.----- 9/13/2018 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Risk Strategies Company CONTACT 2040 Main Street, Suite.450 PHONE Risk Strategies Company FAX Irvine, CA 92614 INC.No.Ext(: 949-242-9240 (NC,No): E-MAILDSS: syounq©risk-strategies.com INSURER(S)AFFORDING COVERAGE NAIC# www.risk-strategies.com CA DOI License No.OF06675 INSURERA: Berkshire Hathaway Specialty Insurance Company 22276 INSURED INSURER B: Lloyd's Synd 510 Tokio Marine Kiln AIIN#AA112651C Carollo Engineers, Inc. 2700 Ygnacio Valley Road, #300 INSURERC: Walnut Creek CA 94598 INSURERD: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 44167819 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL SUER POLICY EFF POLICY EXP INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DDIYYYY) LIMITS COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ CLAIMS-MADE OCCUR DAMAGE TO RENTED PREMISES(Ea occurrence) $ MED EXP(Any one person) _ $ PERSONAL&ADV INJURY $ GENL AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ POLICY PRO- JECT LOC PRODUCTS-COMP/OP AGG $ OTHER: $ I AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ (Ea accident) _ ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ '1 AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY (Per accident) $ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ A Technology Professional Liability 47EPP30272803 7/4/2018 7/4/2019 Each Claim/Aggregate $1,000,000 B Cyber Liability 1111546 9/15/2018 9/15/2019 Each Claim/Aggregate $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Projects as on file with the insured including but not limited to:For any and all work performed on behalf of Collier County,including Contract#17-7117 for SCRWTP Reactor Tank Number Four.Carollo project#not yet assigned. CERTIFICATE HOLDER CANCELLATION Collier CountyBoard of CountyCommissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 3295 Tamiami Trail E. ACCORDANCE WITH THE POLICY PROVISIONS. Naples FL 34112 AUTHORIZED REPRESENTATIVE -I. <.1.-.'>-//::1--"..:'.r.C-. ('—' 4.--:44-4- / I Michael Christian ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 44167819 1 18-19 Tech E&O-Cyber 1 Sherry Young 19/13/2018 7,46:07 AM (PDT) 1 Page 1 of 1 CNA Blanket Additional Insured - Owners, Lessees or Contractors - with Products-Completed Operations Coverage Endorsement This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is understood and agreed as follows: I. The WHO IS AN INSURED section is amended to add as an Insured any person or organization whom the Named Insured is required by written contract to add as an additional insured on this coverage part, including any such person or organization, if any, specifically set forth on the Schedule attachment to this endorsement. However, such person or organization is an Insured only with respect to such person or organization's liability for: A. unless paragraph B. below applies, 1. bodily injury, property damage, or personal and advertising injury caused in whole or in part by the acts or omissions by or on behalf of the Named Insured and in the performance of such Named Insured's ongoing operations as specified in such written contract; or 2. bodily injury or property damage caused in whole or in part by your work and included in the products-completed operations hazard, and only if a. the written contract requires the Named Insured to provide the additional insured such coverage; and b. this coverage part provides such coverage. B. bodily injury, property damage, or personal and advertising injury arising out of your work described in such written contract, but only if: 1. this coverage part provides coverage for bodily injury or property damage included within the products completed operations hazard; and 2. the written contract specifically requires the Named Insured to provide additional insured coverage under the 11-85 or 10-01 edition of CG2010 or the 10-01 edition of CG2037. II. Subject always to the terms and conditions of this policy, including the limits of insurance, the Insurer will not provide such additional insured with: A. coverage broader than required by the written contract; or B. a higher limit of insurance than required by the written contract. III. The insurance granted by this endorsement to the additional insured does not apply to bodily injury, property damage, or personal and advertising injury arising out of: A. the rendering of, or the failure to render, any professional architectural, engineering, or surveying services, including: 1. the preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; and 2. supervisory, inspection, architectural or engineering activities; or B. any premises or work for which the additional insured is specifically listed as an additional insured on another endorsement attached to this coverage part. IV. Notwithstanding anything to the contrary in the section entitled COMMERCIAL GENERAL LIABILITY CONDITIONS, the Condition entitled Other Insurance, this insurance is excess of all other insurance available to the additional insured whether on a primary, excess, contingent or any other basis. However, if this insurance CNA75079XX(1-15) Policy No: 6050490317 Page 1 of 2 Endorsement No: Effective Date:12/31/2017 Insured Name: Carollo Engineers, Inc. Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office,Inc.,with its permission. 43680840 1 `17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks 18/16/2018 3:20:59 PM (PDT) 1 Page 2 of 8 CNA Blanket Additional Insured - Owners, Lessees or Contractors - with Products-Completed Operations Coverage Endorsement is required by written contract to be primary and non-contributory, this insurance will be primary and non- contributory relative solely to insurance on which the additional insured is a named insured. V. Solely with respect to the insurance granted by this endorsement, the section entitled COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: The Condition entitled Duties In The Event of Occurrence, Offense, Claim or Suit is amended with the addition of the following: Any additional insured pursuant to this endorsement will as soon as practicable: 1. give the Insurer written notice of any claim, or any occurrence or offense which may result in a claim; 2. except as provided in Paragraph IV. of this endorsement, agree to make available any other insurance the additional insured has for any loss covered under this coverage part; 3. send the Insurer copies of all legal papers received, and otherwise cooperate with the Insurer in the investigation, defense, or settlement of the claim; and 4. tender the defense and indemnity of any claim to any other insurer or self insurer whose policy or program applies to a loss that the Insurer covers under this coverage part. However, if the written contract requires this insurance to be primary and non-contributory, this paragraph (4) does not apply to insurance on which the additional insured is a named insured. The Insurer has no duty to defend or indemnify an additional insured under this endorsement until the Insurer receives written notice of a claim from the additional insured. VI. Solely with respect to the insurance granted by this endorsement, the section entitled DEFINITIONS is amended to add the following definition: Written contract means a written contract or written agreement that requires the Named Insured to make a person or organization an additional insured on this coverage part, provided the contract or agreement: A. is currently in effect or becomes effective during the term of this policy; and B. was executed prior to: 1. the bodily injury or property damage; or 2. the offense that caused the personal and advertising injury for which the additional insured seeks coverage. Any coverage granted by this endorsement shall apply solely to the extent permissible by law. All other terms and conditions of the Policy remain unchanged. This endorsement, which forms a part of and is for attachment to the Policy issued by the designated Insurers, takes effect on the effective date of said Policy at the hour stated in said Policy, unless another effective date is shown below, and expires concurrently with said Policy. CNA75079XX(1-15) Policy No:6050490317 Page 2 of 2 Endorsement No: Effective Date:12/31/2017 Insured Name: Carollo Engineers, Inc. Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office,Inc.,with its permission. 43680840 1 *17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks 18/16/2018 3:20:55 PM (PDT) 1 Page 3 of 8 CNA NOTICE OF CANCELLATION TO CERTIFICATEHOLDERS It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Certificateholders at least 30 days in advance of the date cancellation is effective. If notice is mailed, then proof of mailing to the last known mailing address of the Certificateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. Collier County Board of County Commissioners 3295 Tamiami Trail E. Naples FL 34112 CNA68021XX(2-13) Policy No: 6050490317 Page 1 Endorsement No: Effective Date: 12/31/2017 Insured Name: Carollo Engineers,Inc. ©CNA All Rights Reserved. 43680840 1 "17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) I Leanne Hendricks 18/16/2018 3:20:55 PM (PDT) 1 Page 4 of 8 CNA NOTICE OF CANCELLATION TO CERTIFICATEHOLDERS It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Certificateholders at least 30 days in advance of the date cancellation is effective. If notice is mailed, then proof of mailing to the last known mailing address of the Certificateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. Collier County Board of County Commissioners 3295 Tamiami Trail E. Naples FL 34112 CNA68021XX(2-13) Policy No: 6050490267 Page 1 Endorsement No: Effective Date: 12/31/2017 Insured Name: Carollo Engineers, Inc. ©CNA All Rights Reserved. 43680840 1 '17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks 18/16/2018 3:20:55 PM (PDT) 1 Page 5 of 8 WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 0313 (Ed.4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule ANY PERSON OR ORGANIZATION ON WHOSE BEHALF YOU ARE REQUIRED TO OBTAIN THIS WAIVER OF OUR RIGHT TO RECOVER FROM UNDER A WRITTEN CONTRACT OR AGREEMENT. THIS ENDORSEMENT DOES NOT APPLY IN NJ. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective 12/31/2017 Policy No.6050490270 Endorsement No. Insured Carollo Engineers, Inc. 6050490298 / Insurance Company American Casualty Company of Reading,PA Countersigned by Valley Forge Insurance Company WC 00 03 13 (Ed.4-84) Copyright 1983 National Council on Compensation Insurance. 43680840 1 *17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks 1 8/16/2018 3:20:55 PM (PDT) 1 Page 6 of 8 Carollo Engineers, Inc. CNA . NOTICE OF CANCELLATION TO CERTIFICATEHOLDERS It is understood and agreed that: If you have agreed under written contract to provide notice of cancellation to a party to whom the Agent of Record has issued a Certificate of Insurance, and if we cancel a policy term described on that Certificate of Insurance for any reason other than nonpayment of premium, then notice of cancellation will be provided to such Certificateholders at least 30 days in advance of the date cancellation is effective. If notice is mailed, then proof of mailing to the last known mailing address of the Certificateholder on file with the Agent of Record will be sufficient to prove notice. Any failure by us to notify such persons or organizations will not extend or invalidate such cancellation, or impose any liability or obligation upon us or the Agent of Record. All other terms and conditions of the policy remain unchanged. This endorsement, which forms a part of and is for attachment to the policy issued by the designated Insurers, takes effect on the Policy Effective date of said policy at the hour stated in said policy, unless another effective date (the Endorsement Effective Date) is shown below, and expires concurrently with said policy unless another expiration date is shown below. oU5U4yUZ/U Form No:CC68021 A(02-20131 Policy No:6050490298 Endorsement Effective Date:12/31/2017 Policy Effective Date: 12/31/2017 Endorsement No: Underwriting Company:• American Casualty Company of Reading,PA Valley Forge Insurance Company ®CNA All Rights Reserved. Workers Compensation 43680840 1 *17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks 1 8/16/2018 3)20:55 PM (PDT) 1 Page 7 of 8 CNA PROFESSIONAL LIABILITY AND POLLUTION For All the Commitments you Make INCIDENT LIABILITY INSURANCE POLICY INSURED: Carollo Engineers, Inc. Policy AEH288354410 Effective /4/2018 Endorsement Number NOTICE ENDORSEMENT — CANCELLATION OR NON—RENEWAL We agree with you that your Policy is amended to include the following additional provisions. 1. Your Policy will not be: XX Cancelled by us until we provide at least: 10 days prior written notice if we cancel your Policy for Non-payment of Premium; 30 days prior written notice if we cancel your Policy for The following reasons: Any reason other than non-payment of premium. Non-renewed by us until at least days prior written notice is given to the person or entity named in 2. below. 2. Person or Entity: Collier County Board of County Commissioners 3295 Tamiami Trail E. Naples FL 34112 All other terms and conditions of the Policy remain unchanged. This endorsement, which forms a part of and is for attachment to the Policy issued by the designated Insurers, takes effect on the effective date of said Policy at the hour stated in said Policy and expires concurrently with said Policy unless another effective date is shown above. By Authorized Representative James F. Willging (No signature is required if issued with the Policy or if it is effective on the Policy Effective Date) James F. Willging Countersigned by Authorized Representative 256423 (Ed. 10/05) 43680840 I *17-18 GL-AL-UL-WC 18-19 PL ($1M/$1M) 1 Leanne Hendricks I 8/16/2018 3:20:55 PM (PDT) I Page 8 of 8