Loading...
Agenda 12/13/2016 Item #16D20 16.D.20 12/13/2016 EXECUTIVE SUMMARY Recommendation to approve Change Order No. 5 for Contract No. 13-6178, Construction, Engineering and Inspection (CEI) Services,with Hole Montes, Inc. to increase the contract amount by $103,000 for the Vanderbilt Beach MSTU Utility Conversion Project Phases H and HI. OBJECTIVE: To provide continuous CEI services throughout the construction process for the Vanderbilt Beach Aerial to Underground Utility Conversion. CONSIDERATIONS: The Board awarded Contract No. 13-6178 to Hole Montes, Inc. on April 4, 2014 to provide CEI, surveying, and engineering services for Phases II and III of the Vanderbilt Beach MSTU Utility Conversion Project at a value of$546,093 (Agenda item 16D2). Change Order Nos. 1 through 3 increased the award by a total of$40,400 for additional required surveying services. On March 3, 2016, inspection of the work performed by the excavation contractor disclosed issues with the installation of 12 FPL vaults, which required stopping work on the FPL network until a resolution was reached on July 15, 2016. Change Order No. 4 was executed on July 14, 2016 to: (1)move money within the contract to cover the unexpected CEI services needed to correct the issues found with the vaults, and(2) extend the contract date from August 24, 2016 to April 17, 2017. That extension of time also provided an opportunity to more precisely determine how much additional money and time would be required to complete the project. The original contract in the aerial to underground conversion project was with Hole Montes and there have been six contracts that require CEI services since then. The original length and cost of the Hole Montes contract was estimated based on the plan designs and a project length of service. Delays in the construction of FPL and Comcast networks, and the addition of a contract to install the CenturyLink network, added additional CEI hours that could not have been anticipated and requested in the original contract. The Comcast network was delayed by over two months by Comcast contractual obligations to the 2016 Olympics. The FPL network installation has been on hold since September 1, because of FPL's initial rejection of the as-built construction prints. Change Order No. 5 increases the contract by $103,000 or 17.56 percent. The increase sought provides for $88,000 of additional CEI services to cover construction monitoring of several utility companies and $15,000 to cover increased requirements for record drawing preparation. The additional CEI services are required because the underlining construction has been taking longer than anticipated. These types of delays are not typical for County managed projects. The delays and cost increased are due to the fact that this project required coordination with four(4) separate utility companies who have control of the design and implementation schedules. All of these issues were explained to the Vanderbilt Beach MSTU Advisory Board and they voted to recommend approval of this modification by a vote of 4-0 on November 3, 2016. FISCAL IMPACT: All expenditures associated with this project are paid for by the benefitting property owners. $103,000 is available in the project budget to cover the additional cost for this work. GROWTH MANAGEMENT IMPACT: There is no impact on the Growth Management Plan. LEGAL CONSIDERATIONS: This item is approved as to form and legality, and requires majority vote for Board approval.-SRT RECOMMENDATION: That the Board of County Commissioners approves Change Order No. 5 for Contract No. 13-6178 awarded to Hole Montes, Inc. authorizing an increase of $103,000 for CEI and Packet Pg. 1677 16.D.20 12/13/2016 other related consultant services required for the completion of Vanderbilt Beach MSTU Utility Conversion Project Phases II and III. Prepared by: Harry Sells, Project Manager, Public Transit&Neighborhood Enhancement Division ATTACHMENT(S) 1. 13-6178 Hole Montes Contract (PDF) 2.Hole Montes CO#5 Signed CAO (PDF) 3.Hole Montes Proposal CO#5a (PDF) Packet Pg. 1678 16.D.20 12/13/2016 COLLIER COUNTY Board of County Commissioners Item Number: 16.D.20 Item Summary: Recommendation to approve Change Order No. 5 for Contract No. 13-6178, Construction, Engineering and Inspection (CEI) Services, with Hole Montes, Inc. to increase the contract amount by$103,000 for the Vanderbilt Beach MSTU Utility Conversion Project Phases II and III. Meeting Date: 12/13/2016 Prepared by: Title: Project Manager—Public Transit &Neighborhood Enhancement Name: Harry Sells 11/08/2016 11:07 AM Submitted by: Title: Division Director-Pub Tran&Nbrhd Enh—Public Transit&Neighborhood Enhancement Name: Michelle Arnold 11/08/2016 11:07 AM Approved By: Review: Procurement Services Lissett DeLaRosa Level 1 Purchasing Gatekeeper Completed 11/08/2016 11:33 AM Public Transit&Neighborhood Enhancement Michelle Arnold Additional Reviewer Completed Procurement Services Sandra Herrera Additional Reviewer Completed 11/09/2016 3:38 PM Procurement Services Ted Coyman Additional Reviewer Completed 11/14/2016 9:26 AM Procurement Services Rhonda Burns Additional Reviewer Completed 11/15/2016 3:49 PM Public Services Department Amanda O.Townsend Additional Reviewer Completed 11/16/2016 9:01 AM Public Services Department Hailey Margarita Alonso Additional Reviewer Completed 11/16/2016 4:34 PM Public Services Department Steve Carnell Level 2 Division Administrator Review Completed 11/18/2016 8:24 AM County Attorneys Office Scott Teach Additional Reviewer Completed 11/18/2016 2:32 PM County Attorneys Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 11/18/2016 4:02 PM Office of Management and Budget Valerie Fleming Level 3 OMB Gatekeeper Review Completed 11/21/2016 9:53 AM Budget and Management Office Ed Finn Additional Reviewer Completed 11/30/2016 9:48 AM Budget and Management Office Mark Isackson Additional Reviewer Completed 11/30/2016 12:00 PM County Manager's Office Nick Casalanguida Level 4 County Manager Review Completed 12/06/2016 12:20 PM Board of County Commissioners MaryJo Brock Meeting Pending 12/13/2016 9:00 AM Packet Pg. 1679 16.D.20.a Contract#13-6178 Construction, Engineering, and Inspection (CEI) Services for Vanderbilt MSTU: • Utility Conversion Phase I!, III, and IV N PROFESSIONAL SERVICES AGREEMENT 0 c0 THIS AGREEMENT is made and entered into this ` day off ( 2014, by and M between the Board of County Commissioners for Collier County, Florida, a political subdivision w of the State of Florida (hereinafter referred to as the "COUNTY" or "OWNER") and Hole o Montes, Inc., authorized to do business in the State of Florida, whose business address is 950 Encore Way, Naples Florida 34110 (hereinafter referred to as the "CONSULTANT"). WITNESSETH: o WHEREAS, the OWNER desires to obtain the professional Consulting services of the CONSULTANT concerning Construction, Engineering, and Inspection (CE!) Services for Vanderbilt MSTU: Utility Conversion Phase II, III, and IV (hereinafter referred to as the 0.co 0 "Project"), said services being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and N WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. U N NOW, THEREFORE, in consideration of the mutual covenants and provisions contained I' herein, the parties hereto agree as follows: a, 0 Z ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to OWNER professional Construction, Engineering, and L Inspection (CEI) Services in all phases of the Project to which this Agreement applies. Packet Pg. 1680 16.D.20.a 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the -- Scope of Services described in detail in Schedule A. The total compensation to be paid o CONSULTANT by the OWNER for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. c 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards 3 L and other governmental agencies responsible for regulating and licensing the professional �° services to be provided and performed by the CONSULTANT pursuant to this Agreement. L 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a . professional service which, under Florida Statutes, requires a license, certificate of authorization o or other form of legal entitlement to practice such services, it shall employ and/or retain only E 0 qualified personnel to provide such services to OWNER. c 1.5. CONSULTANT designates George H. Hermanson, P.E., a qualified licensed 0 professional to serve as the CONSULTANT'S project coordinator (hereinafter referred to as the 14 "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the T. services to be provided and performed under this Agreement. Further, the Project Coordinator 0 has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by r CONSULTANT from the Project without OWNER'S prior written approval, and if so removed 2 must be immediately replaced with a person acceptable to OWNER. E ^ U t4 Packet Pg. 1681 _' 16.D.20.a 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from Owner to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any N personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to 0 provide and perform services or work pursuant to the requirements of this Agreement, said co T request may be made with or without cause. Any personnel so removed must be immediately M replaced with a person acceptable to OWNER. r- 0 0 U L 1.7. The CONSULTANT represents to the OWNER that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive 1 experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to 2 the OWNER'S review and approval and shall be in accordance with the generally accepted o 2 standards of professional practice in the State of Florida, as well as in accordance with all 0 applicable laws, statutes, including but not limited to the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, the Florida Public Records Law Chapter 119 (including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(d) and (3)), ordinances, 0 codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Project or the 4 CV services to be provided and performed by CONSULTANT hereunder. In the event of any T.conflicts in these requirements, the CONSULTANT shall notify the OWNER of such conflict and 0 utilize its best professional judgment to advise OWNER regarding resolution of each such conflict. OWNER'S approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of i co the Project. r M T C 1.7.1 The County reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state 3 Packet Pg. 1682 16.D.20.a and/or federal requirements and/or codes and ordinances applicable to Consultant's — performance of the work as related to the project. This list is not deemed to be all-inclusive, and 0 the County reserves the right to make sole determination regarding deductions. After notification L of deficiency, if the Consultant fails to correct the deficiency within the specified timeframe, o U these funds would be forfeited by the Consultant. The County may also deduct or charge the Consultant for services and/or items necessary to correct the deficiencies directly related to the Consultant's non-performance whether or not the County obtained substitute performance. ro w 0 U 1.8. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm L or organization, without OWNER'S prior written consent, or unless incident to the proper 0L performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public . U information concerning the services to be rendered by CONSULTANT hereunder, and o L CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to e 0 comply with the provisions of this paragraph. CONSULTANT shall provide OWNER prompt o written notice of any such subpoenas. C) E E 0 1.9 As directed by OWNER, all plans and drawings referencing a specific geographic area must be submitted in an AutoCad Digital Exchange File (DXF) format on a CD or DVD, drawn in M the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (S- o a) (Half or Quarter Sections are also acceptable), or when implemented, derived from the o 2 RTK(Real-Time Kinematic) GPS Network as provided by OWNER. Information layers shall have o x common naming conventions (i.e. right-of-way - ROW, centerlines - CL, edge-of-pavement - co EOP, etc), and adhere to industry standard CAD specifications. v U CC w 4 Packet Pg. 1683 16.D.20.a ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT If authorized in writing by OWNER through a Change Order to this Agreement, CONSULTANT = 0 shall furnish or obtain from others Additional Services of the types listed in Article Two herein. ti The agreed upon scope, compensation and schedule for Additional Services shall be set forth in M the Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as o U established in OWNER'S Purchasing Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by OWNER as indicated in Article Five t and Schedule B. Except in an emergency endangering life or property, any Additional Services o must be approved in writing via an Amendment to this Agreement prior to starting such services. L OWNER will not be responsible for the costs of Additional Services commenced without such o, 0 express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (1) a waiver of any claim by CONSULTANT for such Additional y.., Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If OWNER determines that a change in the Agreement is required because of the action taken by CONSULTANT in response 0 to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to OWNER of a the emergency within forty-eight (48) hours from when CONSULTANT knew or should have 2 known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT'S right it otherwise may have had to seek an adjustment to its o compensation or time of performance under this Agreement. The following services, if not 2 otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: co .I.a 2.1. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or 4:— advances advances in connection with the Project. Packet Pg. 1684 16.D.20.a --- 2.2. Services resulting from significant changes in the general scope, extent or character of o the Project or its design including, but not limited to, changes in size, complexity, OWNER'S L schedule or character of construction; and revising studies, reports, design documents or o 0 Contract Documents previously accepted by OWNER when such revisions are required by eNcIl changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT'S control and fault. 0 (j L) 2.3 Providing renderings or models for OWNER'S use. 0 a) C) 2.4 Investigations and studies involving detailed consideration of operations, maintenance 2 and overhead expenses; the preparation of feasibility studies, cash flow and economic c evaluations, rate schedules and appraisals; and evaluating processes available for licensing and 0. tvi0 assisting OWNER in obtaining such process licensing. 0 d 2.5. Furnishing services of independent professional associates and consultants for other 0 than the Basic Services to be provided by CONSULTANT hereunder. CI N 2.6. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by OWNER, other than visits to the Project site or OWNER's office. 0 0 cu 2.7 Preparation of operating, maintenance and staffing manuals, except as otherwise C) provided for herein. o ti 2.8. Preparing to serve or serving as a CONSULTANT or witness for OWNER in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in E U consultations which are included as part of the Basic Services to be provided herein). co 6 Packet Pg. 1685 16.D.20.a 2.9 Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of ---- the Basic Services in accordance with generally accepted professional practice. U ARTICLE THREE OWNER'S RESPONSIBILITIES 3.1. The OWNER shall designate in writing a project manager to act as OWNER'S it representative with respect to the services to be rendered under this Agreement (hereinafter :),T; referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define OWNER'S policies and decisions with respect to CONSULTANT'S services for the Project. However, the Project Manager is not 0 authorized to issue any verbal or written orders or instructions to the CONSULTANT that would s have the effect, or be interpreted to have the effect, of modifying or changing in any way ; 0 whatever: a co (a) The scope of services to be provided and performed by the CONSULTANT °— hereunder; (b) The time the CONSULTANT is obligated to commence and complete all such 0 services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONSULTANT. N ; C6 O 3.2. The Project Manager shall: (a) Review and make appropriate recommendations on all requests submitted by o 2 the CONSULTANT for payment for services and work provided and performed o z in accordance with this Agreement; 9 (b) Provide all criteria and information requested by CONSULTANT as to OWNER's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; Packet Pg. 1686 16.D.20.a (c) Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT'S disposal all available information in the OWNER'S e 0 possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative g to the Project; co (d) Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this ,72) Agreement; and 0 (e) Provide notice to CONSULTANT of any deficiencies or defects discovered by 15' the OWNER with respect to the services to be rendered by CONSULTANT hereunder. co ARTICLE FOUR > TIME 2 0. co 0 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the c 0 execution of this Agreement upon written Notice to Proceed from OWNER for all or any I designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due 0.) to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts .26 of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or i) lock-outs, then CONSULTANT shall notify OWNER in writing within five (5) working days after :19 commencement of such delay, stating the specific cause or causes thereof, or be deemed to (",2 have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 8 Packet Pg. 1687 1 6.D.20.a 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT'S services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONSULTANT of its duty to L N perform or give rise to any right to damages or additional compensation from OWNER. o CONSULTANT'S sole remedy against OWNER will be the right to seek an extension of time to ti 7.r its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. 3 Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided ° hereunder have been delayed for a total of 180 calendar days, CONSULTANT'S compensation shall be equitably adjusted, with respect to those services that have not yet been performed, to 0 F reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of 2 such delays. o a a eu 0 4.4 Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold 0 any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to N reasonably establish to the OWNER's satisfaction that the CONSULTANT'S performance is or ti will shortly be back on schedule. 0 U 4.5 In no event shall any approval by OWNER authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by OWNER to CONSULTANT be 15 deemed a waiver of any right or claim OWNER may have against CONSULTANT for delay or any other damages hereunder. 9 Packet Pg. 1688 16.D.20.a` ARTICLE FIVE COMPENSATION _ 5.1. Compensation and the manner of payment of such compensation by the OWNER for _ services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled c 0 "Basis of Compensation", which is attached hereto and made a part hereof. co ti ARTICLE SIX OWNERSHIP OF DOCUMENTS U 6.1. Upon the completion or termination of this Agreement, as directed by OWNER, ,8 CONSULTANT shall deliver to OWNER copies or originals of all records, documents, drawings, notes, tracings, plans, Auto CADD files, specifications, maps, evaluations, reports and other o technical data, other than working papers, prepared or developed by or for CONSULTANT o, under this Agreement ("Project Documents"). OWNER shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to OWNER the Project Documents. a CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and 2 internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring OWNER to pay any additional compensation, CONSULTANT hereby grants to OWNER a nonexclusive, irrevocable license in all of the Project Documents for OWNER'S use on this Project. CONSULTANT warrants to OWNER that it has full right and authority to grant this license to OWNER. Further, CONSULTANT consents to OWNER'S use of the Project Documents to w complete the Project following CONSULTANT'S termination for any reason or to perform Uo additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges OWNER may be making Project Documents available for review and information to various third parties and hereby consents to such use by OWNER. co ti ARTICLE SEVEN MAINTENANCE OF RECORDS a) 7.1. CONSULTANT will keep adequate records and supporting documentation which concern w i.i or reflect its services hereunder. The records and documentation will be retained by 10 Packet Pg. 1689 16.D.20.a CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. OWNER, or any duly authorized agents or representatives of OWNER, shall, free of charge, have the right to audit, inspect and copy all such records and c documentation as often as they deem necessary during the period of this Agreement and during �o the five (5) year period noted above, or such later date as may be required by law; provided, M however, such activity shall be conducted only during normal business hours. _ ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and 0 hold harmless OWNER, its officers and employees from any and all liabilities, damages, losses (13 and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of 22 CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this 0 igria Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. o ARTICLE NINE INSURANCE M w 0 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the 0 Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 0 2 0 9.2 All insurance shall be from responsible companies duly authorized to do business in the ti State of Florida. .Fa 9.3 All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: a. it Packet Pg. 1690 ) 16.D.20.a 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Government, Collier o County, Florida, as an additional insured as to the operations of CONSULTANT under 2 this Agreement and shall contain a severability of interests provisions. o U co 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against ',L- T T OWNER for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 0 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- °,6 insurance program carried by OWNER applicable to this Project, and the "Other 4.7 Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by OWNER applicable to this Project. cc 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. o 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall 2 be construed in accordance with the laws of the State of Florida. 9.4. CONSULTANT, its subconsultants and OWNER shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by g ce OWNER, except such rights as they may have to the proceeds of such insurance held by any of them. N Yo' 9.5 All insurance companies from whom CONSULTANT obtains the insurance policies c required hereunder must meet the following minimum requirements: c°a 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. co 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class r VI" or higher. E U cc 12 Packet Pg. 1691 16.D.20.a ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT'S own '1., staff, unless otherwise authorized in writing by the OWNER. The employment of, contract with, 11 or use of the services of any other person or firm by CONSULTANT, as independent consultant ti or otherwise, shall be subject to the prior written approval of the OWNER. No provision of this Agreement shall, however, be construed as constituting an agreement between the OWNER t w and any such other person or firm. Nor shall anything in this Agreement be deemed to give any o U such party or any third party any claim or right of action against the OWNER beyond such as ,o may then otherwise exist without regard to this Agreement. d I- 0 a) 10.2 Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed a, 0 to this Project in accordance with the percentages noted in Schedule F. CONSULTANT also 0. has identified each subconsultant and subcontractor it intends to utilize on the Project in P. Schedule F. All personnel, subconsultants and subcontractors identified in Schedule F shall not 7,3 be removed or replaced without OWNER'S prior written consent. E 0 c,, 10.3 CONSULTANT is liable for all the acts or omissions of its subconsultants or & subcontractors. By appropriate written agreement, the CONSULTANT shall require each N subconsultant or subcontractor, to the extent of the Services to be performed by the L id subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this u Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities o a which the CONSULTANT, by this Agreement, assumes toward the OWNER. Each :0 co subconsultant or subcontract agreement shall preserve and protect the rights of the OWNER T under this Agreement with respect to the Services to be performed by the subconsultant or L subcontractor so that the subconsulting or subcontracting thereof will not prejudice such rights. L I3 Packet Pg. 1692 16.D.20.a Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub-subconsultants or sub-subcontractors. 0 10.4 CONSULTANT acknowledges and agrees that OWNER is a third party beneficiary of o U each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship r between OWNER and any subconsultant or subcontractor. Further, all such contracts shall 0 U provide that, at Owner's discretion, they are assignable to OWNER upon any termination of this Agreement. L a> ARTICLE ELEVEN 0 C, WAIVER OF CLAIMS s U 11.1. CONSULTANT'S acceptance of final payment shall constitute a full waiver of any and all o L Q claims, except for insurance company subrogation claims, by it against OWNER arising out of 0 this Agreement or otherwise related to the Project, and except those previously made in writing o in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at 2 512 the time of the final payment. Neither the acceptance of CONSULTANT'S services nor payment 0 by OWNER shall be deemed to be a waiver of any of OWNER'S rights against CONSULTANT. ce ARTICLE TWELVE TERMINATION OR SUSPENSION v L 12.1. CONSULTANT shall be considered in material default of this Agreement and such default 3o will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further c 0 set forth in this section, for any of the following reasons: (a) CONSULTANT'S failure to begin 0 0 services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) _ 03 ti CONSULTANT'S failure to properly and timely perform the services to be provided hereunder or M as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the C, benefit of creditors by CONSULTANT or by any of CONSULTANT'S principals, officers or L U fC directors, or (d) CONSULTANT'S failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT'S failure to perform or abide by the terms and 14 Packet Pg. 1693 16.D.20.a conditions of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. F.12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it co' r is determined for any reason that CONSULTANT was not in default, or that its default was W excusable, or that OWNER otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 3 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and 15 CONSULTANT's remedies against OWNER shall be the same as and be limited to those L afforded CONSULTANT under paragraph 12.3, below. 12.3. OWNER shall have the right to terminate this Agreement, in whole or in part, without o cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such 0 0 termination for convenience, CONSULTANT'S recovery against OWNER shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the 0 termination, but CONSULTANT shall not be entitled to any other or further recovery against OWNER, including, but not limited to, anticipated fees or profits on work not required to be `c7.1 performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably v possible. 0 U N a) 12.4. Upon termination and as directed by Owner, the CONSULTANT shall deliver to the OWNER all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Section 6, that are in 9 CONSULTANT'S possession or under its control. :"- _ v E L 12.5. The OWNER shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior 15 Packet Pg. 1694 16.D20.a' written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT'S sole and exclusive remedy shall be to seek an 0 extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 0 U 00 T 12.6 In the event (i) OWNER fails to make any undisputed payment to CONSULTANT within M forty-five (45) days after such payment is due or such other time as required by Florida's Prompt w Payment Act or (ii) OWNER otherwise persistently fails to fulfill some material obligation owed 0 by OWNER to CONSULTANT under this Agreement, and (ii) OWNER has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving OWNER a second fourteen (14) days written notice of CONSULTANT's intention to stop 2 performance under the Agreement. If the Services are so stopped for a period of one hundred o L and twenty (120) consecutive days through no act or fault of the CONSULTANT or its 0 subconsultant or subcontractor or their agents or employees or any other persons performing 0 portions of the Services under contract with the CONSULTANT, the CONSULTANT may -2 terminate this Agreement by giving written notice to OWNER of CONSULTANT'S intent to 0 terminate this Agreement. If OWNER does not cure its default within fourteen (14) days after receipt of CONSULTANT'S written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the OWNER, terminate the Agreement and recover from the Owner payment for Services performed through the termination date, but in no event shall 0 CONSULTANT be entitled to payment for Services not performed or any other damages from u, Owner. a 0 ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company E E or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, Q 16 Packet Pg. 1695 16.D.20.a' company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent y-- upon or resulting from the award or making of this Agreement. Y U 13.2. In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the o0 T CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto M and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs supporting the compensation for CONSULTANT'S services to be provided under this 0 Agreement are accurate, complete and current at the time of the Agreement. The 2 CONSULTANT agrees that the original Agreement price and any additions thereto shall be t adjusted to exclude any significant sums by which the OWNER determines the Agreement price o was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit 2 U costs. All such adjustments shall be made within one (1) year following the end of this cp 0 L a Agreement. 0 0 ARTICLE FOURTEEN CONFLICT OF INTEREST CD 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, 0 either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest N shall be employed to perform those services. 0 ARTICLE FIFTEEN MODIFICATION 2 w 15.1. No modification or change in this Agreement shall be valid or binding upon either party T unless in writing and executed by the party or parties intended to be bound by it. 17 Packet Pg. 1696 16.D.20.a ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the 5 F. CONSULTANT to the OWNER shall be in writing and shall be delivered by hand, by fax, or by Z 0 United States Postal Service Department, first class mail service, postage prepaid, addressed to v co ti the following OWNER'S address of record: M Board of County Commissioners Collier County Florida Purchasing Department 0 3327 Tamiami Trail East Naples, FL 34112 Attention: Joanne Markiewicz Director, Procurement Services 12 Telephone: 239-252-8407 Fax: 239-252-6480 U 16.2. All notices required or made pursuant to this Agreement to be given by the OWNER to 0 the CONSULTANT shall be made in writing and shall be delivered by hand, by fax or by the i 0 United States Postal Service Department, first class mail service, postage prepaid, addressed to 0 the following CONSULTANT'S address of record: Hole Montes, Inc. 950 Encore Way 0 Naples, FL 34110 George H. Hermanson, Senior Vice President/Principal Telephone: (239) 254-2000 Fax: (239) 254-2099 U RS 16.3. Either party may change its address of record by written notice to the other party given in o accordance with requirements of this Article. c� 0 ARTICLE SEVENTEEN 2 MISCELLANEOUS co ti 17.1. CONSULTANT, in representing OWNER, shall promote the best interests of OWNER and assume towards OWNER a duty of the highest trust, confidence, and fair dealing. E ice. V fC Q 18 Packet Pg. 1697 16.D.20.a 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. U 2 L 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by o U CONSULTANT without the prior written consent of OWNER. co 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of 3 L 0 the terms of this Agreement. 17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this o Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or 52 U change the provisions in such Articles, Schedules, Parts and Attachments. o L a 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth 0 herein, and any such prior agreements or understanding shall have no force or effect whatever I on this Agreement. r.+ U 17.7 Unless otherwise expressly noted herein, all representations and covenants of the parties t 0 shall survive the expiration or termination of this Agreement. 0 a 17.8 This Agreement may be simultaneously executed in several counterparts, each of which o c0 shall be an original and all of which shall constitute but one and the same instrument. r 17.9 The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: I9 Packet Pg.1698 16.D.20.a Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION 0 Schedule C PROJECT MILESTONE SCHEDULE 2 Schedule D INSURANCE COVERAGE '(7) 0 c.) Schedule E TRUTH IN NEGOTIATION CERTIFICATE CO Schedule F KEY PERSONNEL, SUBCONSULTANTS AND ,c7 er, SUBCONTRACTORS "5 RFP# 13-6178 "Construction, Engineering, and Inspection (CE!) Services for .oct Vanderbilt MSTU: Utility Conversion Phase II, Ill, and IV", Terms and ° Lc) Conditions, and Consultant's Proposal 0 OJ ARTICLE EIGHTEEN cr) APPLICABLE LAW c.) 2 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of a Florida, and by such laws, rules and regulations of the United States as made applicable to 8 services funded by the United States government. Any suit or action brought by either party to j this Agreement against the other party relating to or arising out of this Agreement must beE &) brought in the appropriate federal or state courts in Collier County, Florida, which courts have z sole and exclusive jurisdiction on all such matters. a) c.^) (.1 ARTICLE NINETEEN ("5 SECURING AGREEMENT/PUBLIC ENTITY CRIMES 0 C-) (3 19.1 CONSULTANT warrants that CONSULTANT has not employed or retained any company g or person, other than a bona fide employee working solely for CONSULTANT, to solicit or 2a, secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent 7 upon or resulting from the award or making of this Agreement. At the time this Agreement is 2 executed, CONSULTANT shall sign and deliver to OWNER the Truth-In-Negotiation Certificate g identified in Article 13 and attached hereto and made a part hereof as Schedule E. '7 20 Packet Pg. 1699 6.D.20.a CONSULTANT'S compensation shall be adjusted to exclude any sums by which OWNER determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2 By its execution of this Agreement, CONSULTANT acknowledges that it has been 11) 0 informed by OWNER of and is in compliance with the terms of Section 287.133(2)(a) of the c-). Florida Statutes which read as follows: 9 "A person or affiliate who has been placed on the convicted vendor list T. following a conviction for a public entity crime may not submit a bid, 0 proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, c.) subcontractor, or consultant under a contract with any public entity; and 2 may not transact business with any public entity in excess of the threshold co amount provided in s. 287.017 for CATEGORY TWO for a period of 36 0 40-4. months following the date of being placed on the convicted vendor list." ARTICLE TWENTY DISPUTE RESOLUTION C.) 20.1 Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such 0.) disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT cr?, with full decision-making authority and by OWNER'S staff person who would make the 0 presentation of any settlement reached during negotiations to OWNER for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties '6 CD arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation cc shall be attended by representatives of CONSULTANT with full decision-making authority and 9 by OWNER'S staff person who would make the presentation of any settlement reached at mediation to OWNER'S board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 21 .4-- Packet Pg. 1700 16.D.20.a 20.2 Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state o courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. c co ti ARTICLE 21 IMMIGRATION LAW COMPLIANCE 0 21.1 By executing and entering into this agreement, the CONSULTANT is formally cL acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.G. 1324, et d L seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT Ow to comply with the laws referenced herein shall constitute a breach of this agreement and the cc County shall have the discretion to unilaterally terminate this agreement immediately. 0 L ****************** Remainder of page is intentionally left blank ************************* cis rn fSf .b+ Co G OD �a7 cu fC 22 Packet Pg. 1701 16.D.20.a IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement for Contract #13-6178 Construction, Engineering, and Inspection (CEI) ,„--... Services for Vanderbilt MSTU: Utility Conversion Phase II, Ill, and IV the day and year first written above. 13 c 0 c.) ATTEST: BOARD OF COUNTY COMMISSIONERS FOR co COLLIER COUNTY, FLORIDA, ,- DwightE'. Brdck,7Clerk • 4 -.'"'Nk 4 '. • • - I 7 1 iL../1 Z.) fkrttl l' NI j ;''''' By: -- , ,, ,-,...-- Q.... - L____ ,........-j) zi ---'-''''' : , v: / *6 Date. 21 4114i ) 41 ..../ i By:. -----A-,---- --,, - 0 , ,), Attests to Cairrtah's Tom Henning, Chairmieli signature 64: kl * 'Cr> Approved as to Form and Legality: o v3 AS-sistant CoilInty Attdrney c..) o EMI IV \Z. Yep10 Name ' a cc 0 ..i—.. Hole Montes,irr , 4- 03 (.. ., ,, ". "CS C r -'''---: ''' ' C) , -2 ,77*/ E By: - 0 Witness7 / YI .„,--V i). / - C7-eT,'Cl& '1.--- •• Name and Title Name a'nd Title .1. c., \ ,,./ ,--.,c..2)-7/Cli ,„/1.e.):::, ,, ,„,./4.•.5 I '- , 1.5 ,, 'a (--------- - co 4E' Witness - 0 c..) .. , ,./, d-- , pi !, ,c / e:c Jis...5.-- 2 0 CD Name and Title c 0 2 0 0 I Co N. tn , a) 43. 23 Packet Pg. 1702 16.D.20.a SCHEDULE A — SCOPE OF SERVICES Contract#13-6178 Construction, Engineering, and Inspection (CEI) Services for Vanderbilt MSTU: Utility Conversion Phase II, III, and IV o The Vanderbilt Beach MSTU is managing the Project to convert all (FP&L, Comcast, Century Link, w NuVu, and FPL-Fiberlink, (hereafter UTILITY) from aerial to underground. Phase I is nearing completion c and will be used to evaluate the operation in Phase 2, 3, and 4. The Vanderbilt Beach MSTU: Utility 8 Aerial to Underground Conversion Phases 2, 3 and 4 (hereafter PROJECT) provides hurricane 001 protection and aesthetic improvements. Underground conversion of all utility lines is required by FPL in order to remove the existing poles M The CEI services will include the following tasks: Task 1 — CEI Construction Video and Still Photographs Task 2 — Detailed Construction Observation and Documentation 0 Task 3 — CEI Project Management Services Task 4—Additional Services TASK 1 —CONSULTANT(CEI) CONSTRUCTION VIDEO AND PHOTOGRAPHS L 1.1 It will be the Consultant's responsibility to provide a preconstruction video tape in DVD c format documenting the condition of the project area prior to commencement of any work. This 2 video tape should capture pre-project conditions of all private property adjacent to the proposed U project area and public property in the right of way with the intent to document all existing o conditions for use in resolving any post-project private or public property alleged damage a claims. Documentation of identification of locations shown on the video will be via audio or other readily used means. The video is to be submitted to the Project Manager prior to construction commencement for the PROJECT. Video, per Task 1.1, to be provided within two (2) weeks of o issue of Notice to Proceed for the commencement of services per the RFP. 1.2 Construction Photographs: It is the Consultant's responsibility to provide pre-construction and construction progress photographs that help visualize the worksite conditions. Photographs 0 will be taken prior to construction commencement, during and after all milestones and construction steps. The picture subject must be identified as to location either on the picture or ;,i; via separate index. The pictures must be in digital format, date stamped, three (3) Mega pixels N minimum resolution, in color. Pre-Construction Photographs per Task 1.2 covering the complete PROJECT are to be provided within three (3) weeks of issue of Notice to Proceed for the commencement of services per the RFP. o U TASK 2— CONSULTANT(CE!) DETAILED OBSERVATION AND DOCUMENTATION 0 The Consultant will provide Construction Inspectors to observe all construction and testing activities related to the project, installation of related utility boxes, existing driveways, landscape 3 and irrigation systems, miscellaneous masonry and concrete work associated with the trenching t and directional bore activity of the power line burial, and video and testing of existing utilities and improvements within the right of way. Construction documentation will be prepared on the day M the construction activity takes place. All construction documentation and preparation of work orders associated with the restoration will be provided to the County not later than the first working day of the following week or more frequently if requested by the County. The Consultant will provide the following services. A-I � . Packet Pg. 1703 16.D.20.a 2.1 - Construction Observation - The Consultant will conduct on-site observations and inspections of all construction activities on the Project to ensure that all work is completed in accordance with the contract documents submitted to Collier County by UTILITY. The Consultant will inform an on-site representative of the construction contractor of any concerns related to conformance of the work with the contract documents (a concern or an issue) as an attempt to resolve any concern or issue on-site. If the concern or issue is not immediately N resolved in the field, the Consultant will inform the County about the concern or issue within four c (4) business hours of the finding. ti The Consultant will be responsible for investigating any concern or issue and resolving the same through an oral or written directive to the construction contractor and so inform the r County. This protocol will be initiated any time the Consultant becomes aware of any 73 construction that is unsafe, unsatisfactory, faulty or defective, does not conform to the Contract t2 Documents, does not meet the requirements of any inspections, tests or approval required to be 3 made, or has been damaged before final payment. The Consultant may be required to travel to the site immediately to meet with a County t representative, law enforcement, or emergency personnel to resolve an emergency on a twenty four (24) hour basis. The Consultant shall respond to a telephone/beeper and the return calls o shall be made within one (1) hour of notification. d 2.2 - Daily Log and Construction Documentation - Each Consultant will prepare a daily log a, recording all activities and details related to the work completed during each day on a form c approved in advance by the County. Information will be recorded in the daily log on each day construction activities occur. The daily log entries will record all aspects of the construction o during that day including, but not limited to: construction crew (labor) details, equipment used, �`- materials used, compliance testing and inspection performed, site conditions, trench conditions, backfill material used, dewatering methods, compaction methods, location of the work, and all c relevant details related to the Work. The Daily Log will reference the digital photographs and or video taken with appropriate file names and file locations. In addition to the construction details, o the daily log will contain information related to: time and hours on the job site, weather conditions, data pertaining to questions of quantities of materials used, extras or deductions, list re of visiting officials and representatives of manufacturers, fabricators, suppliers and distributors, 04- observations observations in general and specific observations in more detail as in observing test procedures, conformance inspection of materials and fitting, name plate data for equipment and material U installed, and other information requested by the County. The daily log, photograph files and other construction documentation will be provided to the County by the Consultant on a weekly o basis on the first day of the week following the week of daily logs. c) 2.3 - Photographic Record -Consultant will provide a comprehensive digital photographic record of all construction activities related to the project. The digital file names will be referenced in the daily log along with a brief description of the photograph, location, the date = and time of the photograph and the name of the photographer. The digital files will be submitted electronically or in digital CD format weekly to the County along with the construction documentation. The photographs that are part of the weekly report will be printed in high r resolution color, two captioned photos per 8 l2" x 11" sheet, printed one side only. Video will be provided in digital format. [ 2.4 - Observe Regulatory Agency Inspections - The Consultant will accompany visiting inspectors representing any regulatory agencies having jurisdiction over the PROJECT and will a record all discussions and the outcome of these regulatory inspections in the daily logs. A-2 Packet Pg. 1704 16.D.20.a 2.5 — Project Milestone Inspections & Substantial Completion Inspection — The Consultant will conduct milestone inspections during the duration of work by UTILITY. It is anticipated that the milestone completion inspections will be conducted routinely at 21-30 day intervals to coincide with the contractors pay application submittal. The Consultant will perform substantial c3 completion inspections when requested by the construction contractor and coordinated with UTILITY and recommends that the work is sufficiently complete to warrant a substantial o completion inspection. During the substantial completion inspection the Consultant will prepare a punch list of items requiring completion or correction to the satisfaction of the County. The Consultant will be responsible for maintaining the punch-list and issuing updates to the punch- list on a weekly basis. The Consultant will coordinate and participate in the final walk-through to ensure that the punch-list items are completed to the satisfaction of the County. All services a related to the Substantial Completion Inspection shall be performed separately for PROJECT for each member of UTILITY, landscape restoration as a result of the Phase II, III, and IV Project. 3 Coordinate close out of right of way permits. o w 2.6 — Final Completion Inspection - Upon the request of the construction contractor and concurrence of the Consultant and the County, the Consultant will conduct final inspections of portions of the project, as they are finished to determine if construction has been completed in accordance with the Contract Documents and the construction contractor has fulfilled all obligations therein. Based on the results of the final inspection, the Consultant will judge the . work complete or not complete. If the work is judged complete, the Consultant will issue a d "notice of final acceptance and recommendation for final payment". If the work is judged not 'o complete, the Consultant will issue written instructions to the construction contractor identifying a the work judged not complete. Upon provision of the construction contractor evidence or o assurance that the deficiencies noted above have been corrected or completed, a second final c inspection will be scheduled to verify that the outstanding issues have been resolved and the Consultant can issue a "notice of final acceptance and recommendation for final payment". All services related to the Final Completion Inspection shall be provided separately for Vanderbilt Beach MSTU: FPL Underground Conversion project: UTILITY and landscape restoration. E 0 2.7 — Final Construction Certification — Upon issuance of a "notice of final acceptance and & recommendation for final payment" the Consultant will provide a Florida Registered signed and sealed certification by a professional Florida Licensed Consultant in responsible charge of the work provided by the Construction Inspectors stating that the "Project has been completed by 15 the construction contractor in accordance with the Plans and Specifications of the Contract E Documents". All services related to the Final Construction Certification shall be provided o separately for Phase II, Ill, and iV. TASK 3 — CE! PROJECT MANAGEMENT SERVICES 0 3.1 - General Management and Oversight — The Consultant will provide support services i customarily related to the construction observation and inspection of similar projects also 0,2 including, but not limited to: a) Schedule and attend all progress meetings and conferences with the County and r contractors. Prepare agenda and distribute meeting minutes. Prepare a list of issues needing resolutions after every meeting and ensure that they are fulfilled. b) Participate in pre-construction coordination meetings with the County, and UTILITY. Participate in other meetings as described or implied herein. w A-3 Packet Pg. 1705 16.D.20.a c) Attend all project meetings in order to monitor progress, respond to field issues, communicate with the contractor, and coordinate communications with the contractor, project manager, and operational staff at County as needed. d) Respond to Requests for Information from the contractor within three (3) working r days. Coordinate requests with project manager and operational staff at Collier County. e) The Consultant is to review and recommend the approval of payments due to the construction contractor for work within the right of way. The Consultant's u recommendation of any payment requested in an application for payment shall constitute a representation by the Consultant to the County as an experienced and qualified professional, that based on Consultant's onsite observations and inspections of construction in progress; that the construction quantities in the applications for payment accurately reflects the progress of the work and that the work is constructed in accordance with the Contract Documents. The Consultant U will process pay requests in accordance with the Florida Prompt Payment Act. All o incoming pay requests processed by the Consultant shall be mechanically stamped with the date received. Final pay requests will be processed by Collier County. f) Provide construction contract administration consisting of: 1) Review of payment applications, if needed. 2) Review of construction schedule updates and field progress. 3) Review of change order requests and preparation of change orders, if needed. o 4) Assistance in administration of additional work under the Contract 0. Allowance Bid item. 0 5) Review preparation, implementation, and restoration of right of way site -- to the original condition. 6) Review record drawings for completeness and accuracy on a daily basis. g) Coordinate all issues with the County, and UTILITY that may bury their lines during the timeframe and property owners who have been negatively affected by the construction. This will involve the restoration of those affected areas. Provide c timely review, recommendations and approval of shop drawings and submittals. h) Respond to Requests for Information from the contractor within three (3) working N days. Coordinate requests with the project manager, or any other governmental agency staff, as needed. i) Within one week after the construction contractor notifies the Consultant and the County that the Work on the PROJECT (for each Phase) is substantially N complete in accordance with the contract documents, the Consultant will provide a signed and sealed certification by a professional consultant registered in the o State of Florida, that the Work was done under his supervision and performed in 2 accordance with the contract documents, including all approved shop drawings and change orders for each licensed discipline. j) The Consultant's staff assigned to this project must be available during the duration of the project and on an emergency callout situation. 3.2 — Coordination of Shop Drawings, Contract Interpretations and Clarifications — The Consultant will coordinate with the issuance of interpretations and clarifications of Contract Documents during construction. The Consultant shall be responsible for technical review and decisions regarding interpretation and clarification of Contract Documents. The Consultant shall a coordinate decisions and responses with the construction contractor. A-4 Packet Pg. 1706 16.D.20.a 3.3 - Monitor Project Records — The Consultant shall monitor all required PROJECT records, including but not limited to delivery schedules, inventories and construction reports. All material deliveries to the project site and/or staging area are to be noted in daily log. o 3.4 — As Constructed Field Drawings — Each Consultant shall maintain red pencil "mark-up" • N notations and sketches on construction plans that reflect the actual details of constructed c facilities. These Constructed Field Drawings will be used by the Consultant to validate the "As u Built" documentation provided by the construction contractor. The Consultant will notify the construction contractor of any differences in the documents maintained by the general contractor for resolution by the County. ra TASK 4—SERVICES AS NEEDED 0 L O The following services will be provided on an as-needed basis for the project, as determined by Lo the County Project Manager or his designee. *� L 4.1 — Landscape Architectural Services - Provide a professional State of Florida registered Landscape Architect(s) (Chapter 481, Part II, Florida Statutes, Chapter 61G10 Florida Administrative Code) as needed. The landscape architect is responsible for the design of 2 landscape restoration work associated with the burial of power lines on an as needed basis. 2 4.2 — Electrical Engineering Services - Consultant shall employ an electrical engineer, licensed as such in the State of Florida, to review the FP&L underground power conversion o plans. The purpose of the review will be to evaluate the cost-effectiveness of the design and identify features that could be redesigned, down-sized or eliminated for potential cost savings. The Consultant's electrical engineer will coordinate with the County's Project Engineer and 2 report his recommendations for consideration in a written report. The Consultant/electrical engineer will act in a role that is strictly advisory and assumes no responsibility for the accuracy E of the underground power conversion plans, which responsibility remains with FP&L. Furthermore, Consultant/electrical engineer assumes no responsibility with regard to County's decision whether or not to implement any of his recommendations, nor is the County obligated to implement any of same recommendations but will make decisions based upon County's N opinion of its best interest. 4.3 — Additional Services (as authorized) — This Scope of Services is intended to describe all o activities related to the construction observation and inspection services to ensure that the Project is constructed in full accordance with the Contract Documents including the plans and specifications prepared by FP&L/Comcast/Century Link. 0 co co Y.+ Packet Pg. 1707 16.D.20.a SCHEDULE B BASIS OF COMPENSATION TIME AND MATERIAL AND LUMP SUM 2 L 1. MONTHLY STATUS REPORTS 2 B.1.1 As a condition precedent to payment, CONSULTANT shall submit to OWNER as part of v its monthly invoice, a progress report reflecting the Project design and construction status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any then-authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete w of each item. cc B1.1.1 All monthly status reports and invoices shall be mailed to the attention of: c°) Harry Sells, Collier County Alternative Transportation Modes (ATM), 3299 East Tamiami Trail, Suite 103, Naples, FL 34112, telephone: (239) 252-4980. 0 L 2. COMPENSATION TO CONSULTANT -E 0 m B.2.1. For the Basic Services provided for in this Agreement, OWNER agrees to make monthly 2 payments to CONSULTANT based upon CONSULTANT'S Direct Labor Costs and Reimbursable Expenses in accordance with the terms stated below. Provided, however, in no a, event shall such compensation exceed the amounts set forth in the table below. 2 e. a TASK DESCRIPTION LUMP SUM TIME & LUMP SUM f° O OR TIME & MATERIALS NOT 4-i-- MATERIALS TO EXCEED , AMOUNT: 3 1 Consultant (CEI) LS $17,545 Construction Video and E o Photographs ti 2.1 — 2.5 Consultant (CEI) TM $467,856 cc and 3 Detailed Observation & o) Documentation and CEI ($19,494 per month 0, Project Management x 24 months) 15 Services cc cc L 2.6 and Final Completion LS $12,452 f 2 .7 inspection and Final Construction Certification c 4.1 Landscape Architect (as TM $19,440 j needed) w 4.2 Electrical Engineer (as TM $24,800 needed) I o, ti Reimbursables TM 1 $4,000 - TOTAL TIME AND $516.096 f r MATERIALS c TOTAL LUMP SUM $29.997 '' TOTAL PROJECT FEES (Total Tasks 1-4 & $546,093 a Reimbursables) B-1 Packet Pg. 1708 16.D.20.a B.2.2. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT'S personnel, with respect to this Project, including all indirect payroll s related costs and fringe benefits, all in accordance with and not in excess of the rates set '76 forth in the Attachment I to this Schedule B. 2 B.2.3. With each monthly Application for Payment, CONSULTANT shall submit detailed time 3, records, and any other documentation reasonably required by OWNER, regarding CONSULTANT'S Direct Labor Costs incurred at the time of billing, to be reviewed and approved by OWNER. B.2.4 For Additional Services provided pursuant to Article 2 of the Agreement, OWNER agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the 3 services to be provided. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provisions of Section 3.5.1 below. There shall be no overtime pay on Basic Services or 4t Additional Services without OWNER'S prior written approval. 0 B.2.5. The compensation provided for under Sections 2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed is under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such > 2 services. a — B.2.6 Notwithstanding anything in this Agreement to the contrary, CONSULTANT 2 acknowledges and agrees that in the event of a dispute concerning payments for g Services performed under this Agreement, CONSULTANT shall continue to perform the I Services required of it under this Agreement, as directed by OWNER, pending resolution of the dispute provided that OWNER continues to pay to CONSULTANT all amounts that OWNER does not dispute are due and payable. 0 3. SCHEDULE OF PAYMENTS: •• cs, B.3.1. CONSULTANT shall submit, with each of the monthly status reports provided for under a Section 1.1 of this Schedule B, an invoice for fees earned in the performance of Basic r, Services and Additional Services during the subject billing month. Notwithstanding 13 anything herein to the contrary, the CONSULTANT shall submit no more than one invoice 3 per month for all fees and Reimbursable Expenses earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by Owner. Additionally, the number of the purchase order granting approval for such services shall appear on all invoices. co B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt Z-0; and approval of invoices submitted on the date of services or within six (6) months after V completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. B-2 Packet Pg. 1709 16.D.20.a, B.3.2 Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT'S letterhead and must include the Purchase Order Number and the Project name and shall not be submitted more than one time monthly. B.3.3 Notwithstanding anything herein to the contrary, in no event may CONSULTANT'S monthly billings, on a cumulative basis, exceed the sum determined by multiplying the o applicable not to exceed task limits set forth in the table in Section 2.1 by the percentage Owner has determined CONSULTANT has completed such task as of that particular monthly billing. M B.3.4 Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. c0 B.3.5 Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be *� utilized by CONSULTANT for Additional Services, CONSULTANT shall be limited to a c maximum markup of 5% on the fees and expenses associated with such subconsultants o and subcontractors. a) B.3.5.1 Reimbursable Expenses associated with Additional Services must comply with section 112.061, Fla. Stat., or as set forth in the Agreement, be charged without c mark-up by the CONSULTANT, and shall consist only of the following items: a B.3.5.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.5.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by OWNER. Such expenses, if c approved by OWNER, may include coach airfare, standard accommodations and meals, all in 0 accordance with section 112.061, F.S. Further, such expenses, if approved by OWNER, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. M B.3.5.1.3. Permit Fees required by the Project. 11.1 1.+ B.3.5.1.4 Expense of overtime work requiring higher than regular rates approved 0 in advance and in writing by OWNER. B.3.5.1.5 Expense of models for the County's use. B.3.4.1.6 Other items on request and approved in writing by the OWNER. ti B-3 Packet Pg. 1710 16.D.20.a ATTACHMENT 1 TO SCHEDULE B PROFESSIONAL FEE SCHEDULE 0 Principal Engineer $195.00 per hour 4ci Senior Project Manager $165.00 per hour *a; CAD Technician $ 81.00 per hour Senior Inspector $90.00 per hour Principal Surveyor $125.00 per hour co Administrative Assistant $ 62.00 per hour 0 0 Subconsultants Senior Electrical Engineer $155.00 per hour cp Senior Landscape Architect $135.00 per hour 0.3 (13 END OF SCHEDULE B 2 ca 5 c.) CNI 45 4E' 2 cs1 cE' (.) B-4 Packet Pg. 1711 16.D.20.a SCHEDULE C PROJECT MILESTONE SCHEDULE U 2 L Services shall commence upon issuance of a Notice to Proceed. 0 Task No. Task Name/Title Time Span 0° r 1 Consultant (CEI) Construction Video and Occurs simultaneously with Photographs Tasks 2.1 — 2.5 and 3 0 2.1 — 2.5 Consultant (CEI) Detailed Observation and 24 months and 3 Documentation and CEI Project :° Management Services 2.6 and 2.7 Final Completion Inspection and Final Estimate 12 month duration Construction Certification (Occurs after completion of Tasks 2.1 — 2.5 cc 4.1 Landscape Architect (as needed) 24 months ; 0 L Lam. 4.2 Electrical Engineer (as needed) Estimate 90 days durationcc O rta) E E O U C) CA M N U f6 0 U N C) a' 0 a C) O q ti M a' C) E c-i Packet Pg. 1712 16.D.20.a SCHEDULE D INSURANCE COVERAGE 0 (1) The amounts and types of insurance coverage shall conform to the following to minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any T of the below listed minimum required coverages, CONSULTANT must identify on the Certificate M Y of Insurance the nature and amount of such self-insured retentions or deductibles and provide L satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or 3 deductibles will be CONSULTANT'S sole responsibility. L d (2) The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. U d 0 L (3) Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the OWNER or as o specified in this Agreement, whichever is longer. I E 0 (4) Certificates of insurance (3 copies) acceptable to the OWNER shall be filed with the OWNER within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance o polices required shall be provided to OWNER, on a timely basis, if requested by OWNER. Such certificates shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to 74 the OWNER. CONSULTANT shall also notify OWNER, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in r coverages or limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT D-1 Packet Pg. 1713 16.D.20.a shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. (5) All insurance coverages of the CONSULTANT shall be primary to any insurance or "' self insurance program carried by the OWNER applicable to this Project. o co (6) The acceptance by OWNER of any Certificate of Insurance does not constitute approval or agreement by the OWNER that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the 0 requirements of this Agreement. (7) CONSULTANT shall require each of its subconsultants to procure and maintain, until 0 the completion of the subconsultant's services, insurance of the types and to the limits specified 2 U in this Section except to the extent such insurance requirements for the subconsultant are 0 L expressly waived in writing by the OWNER. a 0 (8) Should at any time the CONSULTANT not maintain the insurance coverages required herein, the OWNER may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse OWNER for such costs within thirty (30) days after demand, OWNER has the right to offset these costs from any amount due CONSULTANT under this •`%---' Agreement or any other agreement between OWNER and CONSULTANT. The OWNER shall 0 be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the OWNER to cs purchase such insurance coverages shall in no way be construed to be a waiver of any of its o z rights under the Agreement. (9) If the initial, or any subsequently issued Certificate of Insurance expires prior to the ez completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the OWNER, in triplicate, renewal or replacement Certificate(s) D-2 Packet Pg. 1714 16.D.20.a of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the OWNER with such renewal certificate(s) shall be deemed a 0 material breach by CONSULTANT and OWNER may terminate the Agreement for cause. O U WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY co ti T Required by this Agreement? X Yes No U L (1) Workers' Compensation and Employers' Liability Insurance shall be maintained by the 12 4t CONSULTANT during the term of this Agreement for all employees engaged in the work under ;, this Agreement in accordance with the laws of the State of Florida. The amounts of such o insurance shall not be less than: L U O a. Worker's Compensation - Florida Statutory Requirements 0 b. Employers' Liability (check one, if applicable) $100,000 Each Accident $500,000 Disease Aggregate $100,000 Disease Each Employee 0 X $500,000 Each Accident $500,000 Disease Aggregate $500,000 Disease Each Employee Fd 0 (2) The insurance company shall waive all claims rights against the OWNER and the 0 policy shall be so endorsed. CD CO ti (3) United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. E f4 Applicable X Not Applicable D-3 Packet Pg. 1715 I6.D.20.a (4) Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. U I- L W Applicable X Not Applicable o U co ti COMMERCIAL GENERAL LIABILITY t Required by this Agreement? _X_Yes No (1) Commercial General Liability Insurance, written on an "occurrence" basis, shall be ,2 rt maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, L Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent o Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be > 0 L maintained for a period of not less than five (5) years following the completion and acceptance a by the OWNER of the work under this Agreement. Limits of Liability shall not be less than the °` following: General Aggregate $300,000 0 Products/Completed Operations Aggregate $300,000 Personal and Advertising Injury $300,000 Each Occurrence $300,000 Fire Damage $ 50,000 cc General Aggregate $500,000 0 Products/Completed Operations Aggregate $500,000 N Personal and Advertising Injury $500,000 Each Occurrence $500,000 Fire Damage $ 50,000 0 co X General Aggregate $2,000,000 Products/Completed Operations Aggregate $2,000,000 Personal and Advertising Injury $2,000,000 Each Occurrence $1,000,000 Fire Damage $ 50,000 D-4 Packet Pg. 1716 16.D.20.a (2) The General Aggregate Limit shall apply separately to this Project and the policy shall — be endorsed using the following endorsement wording. "This endorsement modifies insurance c- 0 provided under the following: Commercial General Liability Coverage Part. The General 2 Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects c away from premises owned by or rented to you." Applicable deductibles or self-insured col ti T retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured M retentions carried by the CONSULTANT shall be subject to the approval of the Risk 15, Management Director or his/her designee. 0 (3) The OWNER, Collier County Government, shall be named as an Additional Insured d and the policy shall be endorsed that such coverage shall be primary to any similar coverage o carried by the OWNER. U (4) Coverage shall be included for explosion, collapse or underground property damage claims. 0 (5) Watercraft Liability coverage shall be carried by the CONSULTANT or the 0 SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in subparagraph (1) above if applicable to the completion of the Services under this Agreement. Applicable X Not Applicable M CV U (7) Aircraft Liability coverage shall be carried by the CONSULTANT or the 0 SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the y completion of the Services under this Agreement. 0 a Applicable X Not Applicable 00 ti AUTOMOBILE LIABILITY INSURANCE Required by this Agreement? X Yes No E D-5 Packet Pg. 1717 16.D:20.a (1) Automobile Liability Insurance shall be maintained by the CONSULTANT for the ownership, maintenance or use of any owned, non-owned or hired vehicle with limits of not less than: X Bodily Injury & Property Damage - $ 500,000 Bodily Injury & Property Damage - $1,000,000 M ; fG UMBRELLA LIABILITY 0 U (1) Umbrella Liability may be maintained as part of the liability insurance of the o CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverages required herein and shall include all o coverages on a "following form" basis. (2) The policy shall contain wording to the effect that, in the event of the exhaustion of 6 any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. PROFESSIONAL LIABILITY INSURANCE 0 Required by this Agreement? X Yes No Y V (1) Professional Liability Insurance shall be maintained by the CONSULTANT to insure 8 its legal liability for claims arising out of the performance of professional services under this 0 Agreement. CONSULTANT waives its right of recover against OWNER as to any claims under a, o this insurance. Such insurance shall have limits of not less than: co t- C.1 $ 500,000 each claim and in the aggregate r X $1,000,000 each claim and in the aggregate $2,000,000 each claim and in the aggregate D_6 Packet Pg. 1718 16.D.20.a $5,000,000 each claim and in the aggregate (2) Any deductible applicable to any claim shall be the sole responsibility of the 0 **g CONSULTANT. Deductible amounts are subject to the approval of the OWNER. 2 0 (3) The CONSULTANT shall continue this coverage for this Project for a period of not uo; less than five (5) years following completion and acceptance of the Project by the OWNER. 4E' (4) The policy retroactive date will always be prior to the date services were first 8 performed by CONSULTANT or OWNER, and the date will not be moved forward during the :8 term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit 0 Certificates of Insurance providing for an unqualified written notice to OWNER of any a) cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify OWNER by certified mail, within twenty- E four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material g- 0 change in coverages or limits received by CONSULTANT from its insurer. In the event of more g "1--; than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall 12 immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any if endorsements issued or to be issued on the policy if requested by OWNER. cNi 0 VALUABLE PAPERS INSURANCE '5 (1) In the sole discretion of the County, CONSULTANT may be required to purchase ct valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, () blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or -4F2 co reconstructing valuable papers or records utilized during the term of this Agreement. (,) PROJECT PROFESSIONAL LIABILITY (1) If OWNER notifies CONSULTANT that a project professional liability policy will be IS purchased, then CONSULTANT agrees to use its best efforts in cooperation with OWNER and D-7 Packet Pg. 1719 16.D.20.a OWNER'S insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT'S professional liability policy. If no credit is available from CONSULTANT'S current professional policy .L, underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next o renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent ti T professional liability policies that renew during the term of the project policy). CONSULTANT M agrees that any such credit will fully accrue to OWNER. Should no credit accrue to OWNER, OWNER and CONSULTANT, agree to negotiate in good faith a credit on behalf of OWNER for 3 the provision of project-specific professional liability insurance policy in consideration for a ° xs reduction in CONSULTANT'S self-insured retention and the risk of uninsured or underinsured consultants. cp (2) CONSULTANT agrees to provide the following information when requested by OWNER or OWNER'S Project Manager: o a a a. The date the professional liability insurance renews. o b. Current policy limits. c. Current deductibles/self-insured retention. 03 d. Current underwriter. e. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. o f. Cost of professional insurance as a percent of revenue. g. Affirmation that the design firm will complete a timely project errors and omissions application. N (3) If OWNER elects to purchase a project professional liability policy, CONSULTANT to be L insured will be notified and OWNER will provide professional liability insurance, naming 3- CONSULTANT and its professional subconsultants as named insureds. o 2 co ti END OF SCHEDULED Packet Pg. 1720 16.D.20.a SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE 0 In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida Statutes, Hole Montes, Inc. hereby certifies that wages, rates and other factual unit o costs supporting the compensation for the services of the CONSULTANT to be provided under c the Professional Services Agreement, concerning Contract #13-6178 Construction, Engineering, and Inspection (CE!) Services for Vanderbilt MSTU: Utility Conversion ri Phase II, III, and IV are accurate, complete and current as of the time of contracting. 0 Hole Montes/inc. BY: r 2 ' V FL do s> ii TITLE: � ` 1 ' j°" 0 , � •a DATE: a) M N 0 ao ti M GS �• U E-1 Packet Pg. 1721 16.D.20.a SCHEDULE F KEY PERSONNEL, SUBCONSULTANTS AND SUBCONTRACTORS Principal Engineer (G. Hermanson) 5% Senior Project Manager (T. Cole) 15% Senior Inspector (R. Benza) 100% fC Administrative Assistant (S. Karol) 10% 0 Senior Landscape Architect (D. Slabaugh) As needed Senior Electrical Engineer As needed ;, (Estimated 3 month duration) 0 a)U a> O 0 a) E O C) a, M N 4C) R5 -i 0 0 U) w+ CO a> O N- M a) E Q F-1 Packet Pg. 1722 16.D.20.a ----"" a DATE(MM/DD/YYYY) ACGRD CERTIFICATE OF LIABILITY INSURANCE 3/13/2014 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS 1....Q L-. ERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES .LOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED c .EPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. 0 IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to v the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the E ', certificate holder in lieu of such endorsement(s). H CONTACT C PRODUCER NAME: Kristin Neiert 0 Lutgert Insurance Naples (Poco.No.Exe:239-262-7171 (AA/CC,No):239-262-5360 , PO Box 112500 E-MAIL o o0 Naples FL 34108 ADDREss:kneiertIIlutgertinsurance.com c• INSURER(S)AFFORDING COVERAGE NAIC# 1. INSURER A TRANSPORTATION I Cea INSURED HOLEM-1 INSURERS:CONTINENTAL CA 20443 Hole Montes, Inc INSURER C:FCCI INS CO 110178 IT 950 Encore Way INSURER D:CONTINENTA INS 35289 C Naples FL 34110 INSURER E: (.) INSURER F: 0 COVERAGES CERTIFICATE NUMBER:1180428671 REVISION NUMBER:1 '~ THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD lin INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS �, CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, at EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. 12 INSR ADDL SUBR' POLICY EFF I POLICY EXP 0 W LTR TYPE OF INSURANCE INSR VD I POLICY NUMBER I(MM/DD/YYYY)IIMMIDDIYYYY) LIMITS a) D GENERAL LIABILITY Y 'Y 082970875 1/1/2014 1/1/2015 EACH OCCURRENCE I $1,000,000 Cco DAMAGE TO RENTED $100,000 C X ,COMMERCIAL GENERAL LIABILITY PREMISES(Ea occurrence) CLAIMS-MADE X OCCUR MED EXP(Any one person) $5,000 0 !. X Contractual Liab I PERSONAL 8 ADV INJURY I$1,000,000 9 :, IX Broadened Cover. GENERAL AGGREGATE $2,000,000 2 O. PRODUCTS-COMP/OP AGG $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: Q' POLICY X TA' I I LOCCUMBINcU SINGLE LIMIT 0 �� AUTOMOBILE LIABILITY Y 2082970830 1/1/2014 1/1/2015 (Ea accident) $1,000,000 "" BODILY INJURY(Per person) I$ C X ANY AUTO ALL OWNED. SCHEDULED BODILY INJURY(Per accident)I$ 1 'I. AUTOS AUTOS I $ 'G X • NON-OWNED PROPERTY DAMAGE ( 0 (Per accident) HIRED AUTOS X AUTOS $ E A X UMBRELLA LIAB X OCCUR 2082970567 1/1/2014 1/1/2015 EACH OCCURRENCE $5,000,000 E 0 EXCESS LIAB 11 CLAIMS-MADE AGGREGATE $5,000,000 0 I $ d I DED I, I RETENTION$ ! WC STATU- OTH- re I C WORKERS COMPENSATION Y 11003 1/1/2014 1/1/2015 X I TORY LIMITS I I ER AND EMPLOYERS'LIABILITY , Y/N E.L.EACH ACCIDENT $500,000 — M ANY CER/MEMB PROPRIETOR/PARTNER/EXECUTIVEXCLDN(A (Mandatory n H)EXCLUDED? E.L.DISEASE-EA EMPLOYEE $500,000 (Mandatory in NH) 'If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $500,000 U I B I Professional Liability AEH113988730 11/1/2014 1/1/2015 Per Claim 2,000,000 CS Aggregate 2,000,000 C0 • DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101,Additional Remarks Schedule,If more space is required) Contract#13-5178"CEI Services for Vanderbilt MSTU; Utility Conversion Phase II, Ill and IV" c Holder is Additional Insured with regards to General Liability.*30 Days notice of Cancellation except 10 for Non-Payment of Premium. o a) 0 = ca e` CERTIFICATE HOLDER CANCELLATION m M T SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE r THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN d Collier County Board of County Commissioners- ACCORDANCE WITH THE POLICY PROVISIONS. i-o Administrative Services Division Purchasing Department E 3327 Tamiami Trail East AUTHORIZED REPRESENTATIVE 0 Naples FL 34112-4901 e,-� 4,,,,,Le- / ©1988-2010 ACORD CORPORATION. All rights reserve( ACORD 25(2010/05) The ACORD name and logo are registered marks of ACORD Packet Pg. 1723 _0 .1 01. 9#.1 epic, a6ueg3 anoidde o} uop.epuewwooe : 6P£Z) OVO pau61S 9#00 saloon aloes :;uawt}oefy N NN ti Procurement Service( r YY crxc : co trea Ptflt.0 fit ne14'.+,Wel,_:. .5 V- n Contract Modification ®Work Order Mortification D Amenchnent i r r Contract it: 13-6178 Change II.: 5 � � f urctra.r,r:Order 4: a001o231�I Project II: E N/A 4 J Hole Monies Inc. Project Name: Vanderbilt Beach MSTU Utility Conversion Name: on PTNE(Public Transit&Neighborhood Enhancement) Project Manager Name:l _.__Harry Sails Department: Current BCC Approved Amount w $ 586,493.00 11/10/15 10 E4 Last DCC Approval Date; Agenda item 1t Current Contract/Work Order Amount $ 586,493.00 4/17/2017 SAP Contract Expiration Date (Master) Dollar Amount of this Change $ 103,000.00 26.26% Total Change from Original Amount Revised Contract/Work Order Total $ 689,493.00 17.56% Change from Current LSCC Approved Amount Cumulative Changes $ 143,400.00 17.56% Change from Current Amount _ [_ Completion Bate, Description of the Task(s)Change,and Rationale for the Change Notice to Proceed 8/25/14 Original 8/24/16 Last Approved 4/17/2017 Revised Date f 4/17/2017 Date Completion Date Date (Includes this change) it Of Days Added 0 Select Tasks 0 Add new task(s) 0 Delete task(s) 0 Change task(s) fq other(see below) Provide a response to the following: 1.) detailed and specific explanationtratiionale of the requested change(s)to the task(s)and 1 or the additional clays added (if requested); 2.)Why this change was not included in the original contract; and, 3.) Describe the impact if this change is not processed Attach additional information from the Design Professional and/or Contractor if needed. 1. This CEI and Surveying contract was let to oversee all of the construction activity in the Vanderbilt Utility Conversion Project area which includes Phase, II, Ill,and IV(geographical areas),. The original amount the Work Order of the CEI was an estimate that ,i-..„ was made before any of the contracts were bid.There are six contracts that were or will be performed in this project area requiring CEI oversight. Three are either complete or partially complete. As contracts were ackled,, the CE! services were extended to cover the new contracts but no additional funds were added. 2. This was not included in the original contract because the construction contracts had to be extended to fix issues they encountered when the ground was opened;therefore this CEI contract needs to be increased in value to provide the necessary CEI services while construction is taking place. 3. if the CEI contract is not extended,important observation,recording and advising on the construction process will not be performed which presents the potential for failure. Without the services of the CEI,contractors become self reporting which increases the potential for failure. Task 2.1 -2.5 Total Line item is$491,856, increase line item by$88,000 to$579,856. Task 6.1 Prepare Record Drawings of FPI_Facilities,increase item by$15,000 to from$20,000 to$35,000 /! / rr Prepared by: / 4:r • i e,„/ f.t:``- Date Oct '17, 2016 Harry Sells, P/blic Transit&Neighborhood Enhancement Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the same terms and conditions as contained in the contract/work order indicated above, as fully as if the same were stated in this acceptance, The adjustment,if any, to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/Vendor/Consultant/ Design Professional arising out of or related to the change set forth herein, including claims for impact and delay costs. Accepted by: Date: W.Terry Cele,PE Vice President Hole Montes Inc. Approved by: __._. _ Date: . Michelle Arnold, Director, Public Transit&Neighborhood Enhancement i'1 Approved by: _ , ,h i!'-` Date: Steve Cannell,Administrator,Public Service:s Division Approved by:____ — Date: (Divisions who may requi e additional siig•iatures may include on separate sheet) - . Revised: 10/28(2DI aol S#aapp° a6ueLO anoadde o; uogepuauawooaN : 6tr£Z) OV3 Pau6iS S#03 se;uo j atoH :}uauayoelw N Page 2 of 2,Change Order ti 5 Contract#13-6178,Vanderbilt Beach MSTU Utility Conversion a V a IN WITNESS WHEREOF, the parties hereto, have each, respectively, by an authorized person or agent, have executed this Work Order on the date and year first written below, ATTEST: BOARD OF COUNTY COMMISSIONERS Dwight E. Brock, Clerk of Courts COLLIER COUNTY, FLORIDA By: _ By: Donna Fiala, Chairman Dated: (SEAL) Hole Montes, Inc By: First Witness Signature iType/print signature and titlet tType/print witness namet Second Witness tType/print witness unmet Approved as to Form and Legality: Assistant-County Attorney 4141/ Print Name ao} S#aapa0 aBuey0 anoadde o} uol;epuewwooaa : 6PEZ) es#00 lesodoad sa3uol j aloes :;uewg3e}Iy o n co HOLE MONTESY; ENGINEERS PLANNERS•SURVEYORS to 950 Encore Way•Naples,Florida 34110•Phone 239.254.2000 Fax 239.254.2099 Oct 15, 2016 Harry Sells, MSTU Project Manager Public Transit & Neighborhood Enhancement Division Public Services Department 3299 East Tamiami Trail, Suite 103 Naples, Fla. 34112-5746 Re: Vanderbilt MSTU HM File No. 2011.059 Harry, Thank you for meeting with us this past week to discuss the proposed change order for Mastec, the additional time being added to the project schedule, and the expected completion dates based on the current project status and the remaining work to be completed. To summarize our discussions, the Mastec contract is being extended to December 1, the Century Link bids are in (only one bid received, currently under review), it is estimated that all wiring work by all providers (Summit, Comcast, Century Link, and FPL) will be complete by December 1, FPL Phase 4 plans are not complete yet and there is no timeline on when that may occur, and it will take 60 days +/-to remove all the wires from the poles, have the poles removed and the restoration work completed after all systems are transferred to -- underground service. As you are aware, the challenges presented by this project have resulted in the contractors working extended hours at times and this has resulted in a increase in the number of hours per month that the senior inspector has allocated to the project. These additional hours have depleted the funding at a rate slightly higher than anticipated in the original contact. At this time we currently have $99,248.25 remaining in Tasks 2.1 — 2.5 and 3 Detailed Observation and Documentation and CEI Project Management Services. This is the scope that will require additional funds to continue to provide these services through the duration of Phases 2 and 3 of this contract. If/when Phase 4 design is completed and scheduled we will revisit the time and effort required to complete Phase 4. Based on the current work schedule for the subcontractors on the project, the personnel and estimated hours per month for the additional 5 months are below: Title Hours per month Billing Rate Monthly Total Senior Project Manager (Barry Jones/terry Cole) 24 $165 $ 3,960 Senior Inspector(Ray Benza) 180 $ 90 $16,200 Admin Assistant(S. Karol) 10 $ 62 $ 620 $20,780 5 months at $20780 per month would result in a total change order with the value of$103,900. Of this total, $88,900 of the additional funding would be allocated to Tasks 2.1—2.5 and 3 Detailed Observation H:\8200\A-Marketing\16\BE.T\Vanderbilt MSTU\Hole Montes Proposal CO#6a.docx Naples Fort Myers ao� 5#aepa0 e6uey0 anoadde (3} uol;epuauawooe : 6trEZ) eS# 00 Iesodoad sa;uow aloes :;uewgoefld ti O< N N h p Harry Sells, MSTU Project Manager Public Transit& Neighborhood Enhancement Division a Re:Vanderbilt MSTU HM File No.: 2011.059 E Page 2 a and Documentation and CEI Project Management Services and $15,000 would be dedicated to Task 6.1 Preparation of Record Drawings. If you have any questions or require any further information to initiate the requested change order, please let us know what we can do to be of further assistance. Thank you for the opportunity to work with you on this project and we look forward to continuing the relationship to a successful completion of this project. Very truly yours, HOLE MONTES INC. �r Barry .Jones, Senior Project ` nager HOLE MONTES, INC. 950 Encore Way Naples, Florida 34110 E-mail: barrvjones@hmeng.com Office: (239) 254-2022 Cell: (239) 565-0427 H:\8200\A-Marketing\16\BE.1\Vanderbilt MSTU\Hole Montes Proposal CO#6a.docx