#10-5518 (BQ Concrete, LLC)
A G R E E MEN T 10-5518
for
"Desiqnated Drivewavs for Solid Waste"
THIS AGREEMENT is made and entered into this 27 day of July, 2010, by and between the Board of
County Commissioners for Collier County, Florida, a political subdivision of the State of Florida
(hereinafter referred to as the "County") and B.Q. Concrete, LLC, authorized to do business in the
State of Florida, whose business address is 48 Wickliffe Drive, Naples, Florida 34110 (hereinafter
referred to as the "Contractor").
WIT N E SSE T H:
1. COMMENCEMENT: The contract shall be for a one (1) year period, commencing on July 27,
2010, and terminating July 26, 2011, or until such time as all outstanding Work Orders issued
prior to the expiration of the Agreement period have been completed. This contract shall have
one additional, one (1) year renewal, renewable annually. The County Manager, or his designee,
may, at his discretion, extend the Agreement under all of the terms and conditions contained in
this Agreement for up to one hundred eighty (180) days. The County Manager, or his designee,
shall give the Contractor written notice of the County's intention to extend the Agreement term not
less than ten (10) days prior to the end of the Agreement term then in effect.
2. STATEMENT OF WORK: The Board of County Commissioners deemed three (3) firms to be
pre-qualified and awarded a Contract to each firm. Each awardee will enter into an Agreement to
provide complete services for Designated Driveways on an as-needed basis as may be required
by the County in accordance with the terms and conditions of Bid #10-5518 and the Contractor's
proposal, which is incorporated by reference and made an integral part of this Agreement. The
execution of this Agreement shall not be a commitment to the Contractor that any work will be
awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
Quotation procedure outlined in the next paragraphs and all Work undertaken by Contractor for
County pursuant to this Agreement and that procedure during the term and any extension of the
term of this Agreement.
Prior to the issuance of a Work Order, the County shall provide a summary of Work to be
performed which will afford the Contractor the opportunity to submit a formal quotation for the
Work; the Contractor shall respond with the information sought within seven (7) working days.
For projects with an estimated cost of Fifty Thousand Dollars ($50,000) or less, the County shall
obtain a proposal from one of the awarded Contractor(s), negotiate favorable project terms and
conditions, and issue a Work Order, signed by the Department Director to initiate the projects.
For projects with an estimated cost over Fifty Thousand Dollars ($50,000) and less than One
Hundred Thousand Dollars ($100,000), the department shall quote out the work among all
awarded Contractor(s), or competitively solicit for new quote. The Contractor shall respond with
the information sought within ten (10) working days. The County will negotiate favorable project
terms and conditions, and issue a Work Order, signed by the Department Director and Division
Administrator to initiate the projects.
In each Request for Quotation, the County reserves the right to specify the period of completion
and the collection of liquidated damages in the event of late completion.
Page -1-
3. THE CONTRACT SUM: The County shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation. Any County agency may utilize the services offered under this contract, provided
sufficient funds are included in its budget(s).
4. NOTICES: All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
B.Q. Concrete, LLC
6017 Pine Ridge Road, #329
Naples, FL 34119
Phone: 239-293-8325; Fax: 239-594-5351
Attention: Buddy Quarles
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Collier County Government Complex
Purchasing Department
3301 East Tamiami Trail
Purchasing Building G
Naples, Florida 34112
Attention: Stephen Y. Carnell
Purchasing/General Services Director
Phone: 239-252-8371
Fax: 239-252-6584
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP: Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES: In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. County may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Contractor shall pay all sales,
Page -2-
consumer, use and other similar taxes associated with the Work or portions thereof, which are
applicable during the performance of the Work.
7. NO IMPROPER USE: The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Contract of the Contractor. Should the Contractor fail to correct any
such violation, conduct, or practice to the satisfaction of the County within twenty-four (24) hours
after receiving notice of such violation, conduct, or practice, such suspension to continue until the
violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION: Should the Contractor be found to have failed to perform his services in a
manner satisfactory to the County and requirements of this Agreement, the County may terminate
said Agreement for cause; further the County may terminate this Agreement for convenience with
a seven (7) day written notice. The County shall be sole judge of non-performance.
9. NO DISCRIMINATION: The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
10. INSURANCE: The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits In
compliance with the applicable state and federal laws. The coverage must include
Employers' Liability with a minimum limit of $500,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be
maintained by Contractor during the duration of this Agreement. Renewal certificates shall be
sent to the County ten (10) days prior to any expiration date. There shall be a thirty (30) day
notification to the County in the event of cancellation or modification of any stipulated
insurance coverage.
Page -3-
Contractor shall insure that all subcontractors comply with the same insurance requirements
that he is required to meet. The same Contractor shall provide County with certificates of
insurance meeting the required insurance provisions.
11.INDEMNIFICATION: To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals'
fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the
Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement.
This indemnification obligation shall not be construed to negate, abridge or reduce any other rights
or remedies which otherwise may be available to an indemnified party or person described in this
paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
12 BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be required to
provide Payment and Performance Bonds.
B. When required by County, the Contractor shall furnish a Performance and/or Payment Bond
prior to commencing performance, for the full amount of the Work, which shall act as a
security guaranteeing the performance of the Contractor's work and the payment by the
Contractor to any other party (ies) providing labor and/or materials in connection with each
construction or renovation project performed by the Contractor. The bonds shall be furnished
using the forms prescribed in Exhibit "A".
C. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its
right to do business in the State of Florida, or it ceases to meet the requirements imposed by
the Contract Documents, the Contractor shall, within five (5) calendar days thereafter,
substitute another bond and surety, both of which shall be subject to the County's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide County with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit "C".
14. PAYMENTS WITHHELD. County may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The County may nullify the whole
or any part of any approval for payment previously issued and County may withhold any
payments otherwise due Contractor under this Agreement or any other agreement between
County and Contractor, to such extent as may be necessary in the County's opinion to protect it
from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the
Work by the Contractor; or (g) any other material breach of the Contract Documents.
Page -4-
If any conditions described above are not remedied or removed, County may, after three (3) days
written notice, rectify the same at Contractor's expense. County also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
County, whether relating to or arising out of this Agreement or any other agreement between
Contractor and County.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from specifications
shall be approved in writing by County in advance.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work
of others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as
coordination of all portions of the Work under the Contract Documents, and the coordination
of County's supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work
as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault
or neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the County in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which County may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from County. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against County will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17.CHANGES IN THE WORK. County shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit an itemized estimate of any cost or time increases or savings it foresees as a result
of the change. Except in an emergency endangering life or property, or as expressly set forth
herein, no addition or changes to the Work shall be made except upon written order of County,
and County shall not be liable to the Contractor for any increased compensation without such
written order. No officer, employee or agent of County is authorized to direct any extra or
changed work orally. Any modifications to this Contract shall be in compliance with the County
Purchasing Policy and Administrative Procedures in effect at the time such modifications are
authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an agreement is reached between Contractor and County concerning the
requested changes. Contractor shall promptly perform changes authorized by duly executed
Page -5-
Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change order
in the manner as County and Contractor shall mutually agree.
18. COMPLIANCE WITH LAWS. Contractor agrees to comply, at its own expense, with all federal,
state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable
to the Project, including but not limited to those dealing with taxation, workers' compensation,
equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553,
Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it
shall promptly notify County in writing.
19. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and
waste materials arising out of the Work. At the completion of the Work, Contractor shall remove
all debris, rubbish and waste materials from and about the Project site, as well as all tools,
appliances, construction equipment and machinery and surplus materials, and shall leave the
Project site clean and ready for occupancy by County.
20.ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior
consent in writing of County. If Contractor does, with approval, assign this Agreement or any part
thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the
obligations and responsibilities that Contractor has assumed toward County.
21. WARRANTY. Contractor shall obtain and assign to County all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or fixtures
to be incorporated into the Project. Contractor warrants to County that any materials and
equipment furnished under the Contract Documents shall be new unless otherwise specified, and
that all Work shall be of good quality, free from all defects and in conformance with the Contract
Documents.
Contractor further warrants to County that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from County. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement or
repair. These warranties are in addition to those implied warranties to which County is entitled as
a matter of law.
22.STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent
employees who are physically capable of performing their employment duties. The County may
require the Contractor to remove an employee it deems careless, incompetent, insubordinate or
otherwise objectionable and whose continued employment on Collier County projects is not in the
best interest of the County.
Page -6-
23. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or
regulations of any public authority having jurisdiction over the Project requires any portion of the
Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility
therefore, pay all costs in connection therewith and furnish to the County the required certificates
of inspection, testing or approval. All inspections, tests or approvals shall be performed in a
manner and by organizations acceptable to the County.
24. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any
such loss or damage until final payment has been made. If Contractor or anyone for whom
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of County or County's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the County with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the County's benchmarks, Contractor shall immediately notify County. The
County shall re-establish the benchmarks and Contractor shall be liable for all costs incurred
by County associated therewith.
25. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or
the Work or property at the Project site or adjacent thereto, Contractor, without special instruction
or authorization from County is obligated to act to prevent threatened damage, injury or loss.
Contractor shall give the County written notice within forty-eight (48) hours after the occurrence of
the emergency, if Contractor believes that any significant changes in the Work or variations from
the Contract Documents have been caused thereby.
If the County determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations.
If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the
Contract Amount or an extension to the Contract Time.
26. COMPLETION. When the entire Work (or any portion thereof designated in writing by County) is
ready for its intended use, Contractor shall notify County in writing that the entire Work (or such
designated portion) is substantially complete and request that County issue a Certificate of
Substantial Completion. Within a reasonable time thereafter, County and Contractor shall make
an inspection of the Work (or designated portion thereof) to determine the status of completion. If
County does not consider the Work (or designated portion) substantially complete, the County
shall notify Contractor in writing giving the reasons therefor.
If County considers the Work (or designated portion) substantially complete, County shall prepare
and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall fix the
Page -7-
date of Substantial Completion for the entire Work (or designated portion thereof) and include a
tentative punchlist of items to be completed or corrected by Contractor before final payment.
County shall have the right to exclude Contractor from the Work and Project site (or designated
portions thereof) after the date of Substantial Completion, but County shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance with
the Contract Documents and is ready for final inspection and acceptance, County will make such
inspection and, if County finds the Work acceptable and fully performed under the Contract
Documents, he shall promptly issue a Certificate of Final Completion, Exhibit F, recommending
that on the basis of his observations and inspections, and the Contractor's certification that the
Work has been completed in accordance with the terms and conditions of the Contract
Documents, that the entire balance found to be due Contractor is due and payable. Final
payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit "B".
(2) Consent of Surety (if applicable) to final payment.
(3) If required by County, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by County.
County reserves the right to inspect the Work and make an independent determination as to the
acceptability of the Work. Unless and until the County is completely satisfied, the final payment
shall not become due and payable.
27. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the County. Contractor shall commence the work within five (5) calendar
days from the Commencement Date. No Work shall be performed at the Project site prior to the
Commencement Date. Any Work performed by Contractor prior to the Commencement Date
shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for Quotation.
The date of substantial completion of the Work (or designated portions thereof) is the date
certified by the County when construction is sufficiently complete, in accordance with the Contract
Documents, so County can occupy or utilize the Work (or designated portions thereof) for the use
for which it is intended. The Work shall reach final completion and be ready for final acceptance
by County within the time specified in the Request for Quotation.
County and Contractor recognize that since time is of the essence for any work under this
Agreement, County will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete the
Work within the specified time period, County shall be entitled to assess as liquidated damages,
but not as a penalty, the amount specified in the Request for Quotation for each calendar day
thereafter until substantial completion is achieved.
The Project shall be deemed to be substantially completed on the date the County issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly
waives and relinquishes any right which it may have to seek characterize the above noted
liquidated damages as a penalty, which the parties agree represents a fair and reasonable
Page -8-
estimate of the County's actual damages at the time of contracting if Contractor fails to
substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a Saturday
or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day
shall be omitted from the computation, and the last day shall become the next succeeding day
which is not a Saturday, Sunday or legal holiday.
28. CONTRACT ADMINISTRATION. This Agreement shall be administered on behalf of the County
by the Solid Waste Department.
29. COMPONENT PARTS OF THIS CONTRACT. This Contract consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set out
verbatim, including: Contractor's Proposal, Insurance Certificate, ITB No. 10-5518, any addenda,
any Quotation/Work Order made or issued pursuant to this Agreement, and any related plans or
specifications for any such Quotations or Work Orders.
30.PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or
give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any
County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics
Ordinance No. 2004-05, and County Administrative Procedure 5311. Violation of this provision
may result in one or more of the following consequences: a. Prohibition by the individual, firm,
and/or any employee of the firm from contact with County staff for a specified period of time; b.
Prohibition by the individual and/or firm from doing business with the County for a specified period
of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate
termination of any contract held by the individual and/or firm for cause.
31 SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
32. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. No
markup shall be applied to sales tax.
33.IMMIGRATION LAW COMPLIANCE: By executing and entering into this agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible for
complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8
U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the
Contractor to comply with the laws referenced herein shall constitute a breach of this agreement
and the County shall have the discretion to unilaterally terminate this agreement immediately.
34. VENUE: Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
Page -9-
35 OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES: Collier County encourages and
agrees to the successful proposer extending the pricing, terms and conditions of this solicitation
or resultant contract to other governmental entities at the discretion of the successful proposer.
36.AGREEMENT TERMS: If any portion of this Agreement is held to be void, invalid, or otherwise
unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an authorized
person or agent, hereunder set their hands and seals on the date and year first above written.
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
"-1. ".w.~
By: -ru<<-
Fred W. Coyle, Chairman -
... ..'-' . "" ..:. ' /'
"(,J'~r,' ,,,.
"i7~c;t-llr::',f':'l.,.
. q" iJ. .
~~~ J .\l)~~
First Witness
\J~~~ \~~~(
Type/Print Witness Name
By:
~~
Second . ness
Ignature
~\j~~ ~\~r\p"
yp d Signature
~ -!}})~r \ ~ ~\ ~9~
Title
13\ \~ SMA \W\Qrj lI:..
Type/Print Witness Name
Approved as to form and
lega ff:;;~~
ant County Attorney
~~
Page -10-
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 10-5518
KNOW ALL MEN BY THESE PRESENTS: That
, as
Principal, and , as Surety, located at_
(Business Address)
are held and firmly bound to as
Oblige in the sum of ($) for
the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors
and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the
,20_, with Oblige for
day of
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
20_, the name of under-signed representative, pursuant to authority of its governing
body.
Page -11-
Signed, sealed and delivered
in the presence of:
PRINCIPAL:
Witnesses as to Principal
By:
Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of
,0 ~
corporation, on behalf of the corporation. He/she is personally
as identification and did (did
20_, by _
,a
known to me OR has produced
not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
ATTEST:
SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
Page -12-
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20_, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not) take an
oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -13-
EXHIBIT A-2
PUBUC PERFORMANCE BOND
Bond No.
Contract No. 10-5518
WHEREAS, Principal has entered into a contract dated as of the _ day of
20_, with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because
of any default by Principal under the Contract, including, but not limited to, all delay damages,
whether liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time
specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in
or under the Contract and compliance or noncompliance with any formalities connected with the
Contract or the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page -14-
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this _ day of
20_, the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of :
PRINCIPAL:
Witnesses as to Principal
By:
Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this _ day of
20_, by , as of
, a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -15-
ATTEST:
SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this _ day of
20_, by ,as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not) take an
oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -16-
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and it's
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and County, dated
20_ for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all
charges for labor, materials, supplies, lands, licenses and other expenses for which County might be sued or
for which a lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless County from all demands or suits, actions,
claims of liens or other charges filed or asserted against the County arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS:
President
DATE:
Witnesses
[Corporate Seal]
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this _ day of
, 20_, by
corporation.
of , a
He/she is personally known to me or has produced
as identification and did (did not) take an oath.
, as
corporation, on behalf of the
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commissioner No.:
Page -17-
--,,-,--_..~....__...----,--~~--_.__._--- "~,_.,
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager)
(County Department)
Collier County Board of County Commissioners (the COUNTY) or
Collier County Water-Sewer District (the COUNTY)
FROM:
(Contractor's Representative)
(Contractor's Name)
(Contractor's Address)
RE:
Bid No. 10-5518
Project No.
Application Date
Payment Application No.
for Work accomplished through the Date:
(Project Name)
Original Contract Time:
Revised Contract Time:
Retainage @ 10% thru[insert date] $
Retainage @ _% after [insert date] $
Percent Work completed to Date:
Percent Contract Time completed to Date
%
%
Liquidated Damages to be Accrued $
ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION
Original Contract Amount: $
Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
and stored to Date $
Less previous payment (s) $
AMOUNT DUE THIS
APPLICATION: $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from COUNTY on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through _ inclusive: (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to COUNTY at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to COUNTY); (3) all amounts have
been paid for work which previous payments were issued and received from the COUNTY and that current payment is
now due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be
added to the revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
(Signature) DATE:
(Type Name & Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional:
(DP's Name)
(Signature) DATE:
(Type Name & Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By COUNTY'S Project Manager:
Page -18-
(Signature) DATE:
(Type Name and Title)
EXHIBIT D
CHANGE ORDER
CHANGE ORDER NO.
CONTRACT NO. 10-5518
TO:
DATE:
PROJECT NAME:
PROJECT NO.:
Under our AGREEMENT dated
,20 .
You hereby are authorized and directed to make the following change(s) in accordance with terms and conditions
of the Agreement:
FOR THE (Additive) (Deductive)
Sum of: $
($
Original Agreement Amount $
Sum of Previous Changes $
This Change Order (Add) (Deduct) $
Present Agreement Amount $
The time for completion shall be (increased/decreased) by calendar days due to this Change Order. Accordingly,
the Contract Time is now L---> calendar days. The substantial completion date is and the
final completion date is Your acceptance of this Change Order shall constitute a modification to our
Agreement and will be performed subject to all the same terms and conditions as contained in our Agreement indicated
above, as fully as if the same were repeated in this acceptance. The adjustment, if any, to the Agreement shall constitute a
full and final settlement of any and all claims of the Contractor arising out of or related to the change set forth herein,
including claims for impact and delay costs.
Accepted:
,~
CONTRACTOR:
COUNTY:
BOARD OF COUNTY COMMISSIONERS
OF COLLIER COUNTY, FLORIDA
By:
By:
DESIGN PROFESSIONAL:
By:
Page -19-
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
COUNTY'S Project No.
ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
COUNTY
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
COUNTY, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -20-
The responsibilities between COUNTY and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
COUNTY:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on
,20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
,20_
CONTRACTOR
By:
Type Name and Title
COUNTY accepts this Certificate of Substantial Completion on
,20_
COUNTY
By:
Type Name and Title
Page -21-
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
COUNTY'S Project No.
PROJECT:
ENGINEER'S Project No.
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
COUNTY
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
COUNTY, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page -22-
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on
,20
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
COUNTY accepts this Certificate of Final Completion on
20
COUNTY
By:
Type Name and Title
Page -23-
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free
of all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to F/orida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
Page -24-
Apr. 9. 2010 3:05'M
....--,
PARLIN INS AGENCY 239-263-8696
No. 9175
p, 1/1
~d CERTIFICATE OF LIABILITY INSURANCE I OA'J..(MMTOtJ/'(Yr'Y)
41 9/2010
T~18 C~RTIFICATE IS ISSUEO AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIG~T8 UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOE8 NOT AFFIRMATiVeLY OR NEGATIVELV AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIE8
BELOW. THIS CIiRTIFICATE OF IN8URANCE DOES NOT CONSTITUTE A CONTRACT B!;1WEEN THE ISSUING INSURER{S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If lh. c.rllflc.to holder Ie an ADDITIONAL INSURED, lh. pollcy(lesl most be .n<lors.d. If SUBROGATION IS WAIVED, .ubJect to
the terms; and conditions of the pol'cy. terta'" policies ma~ require an endor..mont. A statement on this certifioattil does not confer rights to the
C&rtlfl,ate holder In lieu of such endors.m.~t(~l: .
PRODuaa P~rlin Insu~anca Agency s~~~~e'f
PO Box 366697 Bonita Sp~inqs, rL 34136 ~ . (239)263-3141 Ir~_N~I:(239)263 8696
24520 Produci:i.ol\ cr., #4 PR DUC:lift
~cn1ta Spring., FL 34135 lN8lJRiR{llI)AFFOftDIHG COVIlJU.Q1. ~A1C.
Itl$UFU!~ HQ CONCIU:T!, INC. INII.UItE~A:NQIl'rHJ}QINTa INS. CO.
itUIIJRiAB:
IlODDY QUAR:L~S INSUMl...e;
4e WICKLlrrZ DR.
NAl?LES, FL 34110 ,NaURER D ~
1)l!!iU~!ItI!:
,1J6URERf"
Policy Number:
0.'" Entered: ~/1/2007
COVERAGES
CERTIFICATE NUMBER'
REVISION NUMBER:
THIS IS iO CERTIFY THAT THE POUCIES Of INSURANCe: LISTED BELOW~AVE BEEN ISSUED TO lHE INSURED NAMED A!:JOVE FOR THE POLICY PERIOD
INolCATED. NOTWITHSTANDING ANY REaUlkEMENT, TERM OR CONDITION OF A,NYCONTMCT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFrCATE MAY BE ISSUED OR MAY PERTAIN, THI! INSUAAt.lCEAF~ORDED BYTHE POLICIES DESCRIBED HER~IN rS SUBJEcT TO All THE TERMS.
EXCLUSIONS AND CONDITIONS OF SUCH POUCI: LIMITS SHOWN MAY IiAVE.aEEN REDUCED BY pAlO CLAIMS.
rll TY!'1i Of IHSURANO! ~~:': 1ft POllCV NUMIlIER !'OLlOY." P uev EXI" LlMITS
OEIiIl""tLJAflILnY :=CURRENCE ,1.,000,000
A :s 5~~EROLAL GENERAll,^, '''TV X 10-0209 </9/2010 /912011 5TORlO.HTEO ,100,000
p .
"'X CLAN$-MA.DE ~ OOCUR ME.O EXP (Mif' a'oI! oe'5<lI1l .5,000
LIMITS ARE AS PERSONAL &: ADV INJURy' $1,000,000
OF lNCEl'UON GEHEftALAGGREGATE ,2,000,000
~'~^(I0~rQ~.!t::llIMIT An8 PER: PRODUCTS. COMp/()p' A.GG 152,000,000
FOllCY PRO. LOC .
~TOM08IL.Ii 1.IA1iI11,ITY COMBINED SINGLE LIMIT ,
(lia=!denl)
- ANy' AUTO BODILY IN"JUR.Y (P~ pm;tII'I) .
- ALL OWN!;;D AUTOS eODIL Y lNJUR.'f lPGI' oocl,jenl) ,
- SCHEDULED AUTOS f'A.OP~lY DAMAOf
.
i- HIREC AUTOS (ParaorJodBilI)
- NON.(JWNEDAUTOa. ,
.
UMBFUiI.LA L.IA. ~ ~CCUR EACH OCCURRI:NCE .
-
IlXCUS wa CLAlMS.MADE AQOR.fOATE ,
- OEDUCT1BLE. ,
RETENllON . ,
WOI{KIiIUI CCM!'iN:lATlON CSTATU..I IqTH
AND IMPlClY.llU;' LlAllLIlY Y IN
ArN PROPRIETOR/PARTNERlEXECUTNE 0 .fA E.L EA-cH ACCIOE:NT .
OFFICERJME.MM:R 9.CLum:D?
{Mll'ldllarylit NHI EL. DISEME - fA EMPLOYE .
~~~~rJ~ ~~~PEAATIQN~ beklw E.L. DISEASI: ~ POllCYllMIT .
r
CIlillCRlPTJON OfOPILRA1l0NS ILOCATIDNlI./VI!KIOlEIi ,,,-lI.r;iOh ACORD 10f, MlIllllonRI R'm~rb 1lI~ltlcfl.ll', If Marl epictl! (<II1l;Ulred~
CONCRE:'JlR CONSTRUCTJ:ON, MASONRY & FE.NCE ERECTION
ADDITIONAL INSURED: COLLI&R COUN~Y BOAnO O~ COMMISSIONERS \
CERTIFICATE HOLDER CANCELLATION \ "\.. >...
COLLIE~ COUNTY BOARD OF COMMI$~ION2RS SKOULO ANY OF T O",_LICIES BE CANCELLEO .EFORE
3301 ~AMI~ t~t E. THE EXPIRATI~~~ttlR.EO, r~ It:L BE DELIVERED IN .
ACOORDANCE S NS.
NAPL"E$, FL 3395"1 AV'"OR".p '''.'''.TAi(V'\ )3'. Y"'=--
FAX:252-6591 ~TTN: EREDA REAVES D~EDRA WILLI~ \ "'-.: \
I
~ 19B6.2~~;CORD COR ORATION. All dghts reserv.d.
ACORD ~5 (2009109 The ACORb nama and la Dare raglstered marks of AC R.P
,
I
I
I
!
) 9
P'roducad ualng rOml! Bo.lS Plu& Bo!lwMI!I. \\IW\II.Fo(msa"$~.t:(Im; 1,1lplllISmij Publi~hlfi!il800.200.19n
JUL-30-2010 13:46 From:
To:2392526597
Page:l/1
CERTIFICATE OF INSURANCE
XX ALLSTATI!!! INSURA~Ce COMPANY DALLSTATE INDeMNlyY COMPANY OAL1.STATE TEXAS 1.l0'(0'$
THIS CERllFlCATE IS ISSUEO ASA MAlTER OF INFORMATION ONLY ANO CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER THIS CERTIFICATE DOES
NOT AMENO, CXiG;ND OR ALTER THE COVERAGE AFFOAoeo 1SV THE POLICIES BELOW.
CE~T1F1CATE HOLDER
N6Ime and Address ot ~m1V to WhOm thia Certifics1e is Issued
Collier County Board of Commissioners
NAMED IN$UIiIl;:O
N,me end Address of Iniiured
BO Concrete LLC
48 Wickliffe Dr.
Naples, FL 34110-1332
TI'Iit; is to certify tnet policies of InsuranC8 lisltld below have been ."s,lled to tho il'\6Ured named abovE! !I;ub]O(t 10 tho QIq)Jration date indIcated below, notwltt'latandll1g sny
rQCllJitB'\'\EInt, tenn or condition of any contract or other document with respecl to whicl1 thl! certificate may be Issuad or tn$y pl;!r1$;n. The insurance affordOd by the pclicie~
dMCribed herein is SUbJect to 311 trlll terms, exclusions, .IiUld col\dibons of such poliCies.
TYPt;: OF INSURANCE AND L1MIT$
COMMERCIAL G6NiRAL LiABILITY Pl,llit.y Effective Expiration
Numoer Date 0.",
Limit Amount
GENERAL AGGREGATE LIMIT (Other than Pr'Oduets. Completed Operations) $
PRODUCTS. COMPlETf;D OPERATIONS AGGREGATE LIMIT $
peRSONAL AND ADVERTISING INJUR.Y LIMit $
EACH OCCURRENCE I.IMfT $
PHySICAL DAMAGE LIMIT $ ANY ON~ LOSS
MEDiCAl EXPENSE LIMIT $ ANY ONE PERSON
WORKERS' COMPENSATION & PoliCy Effective expIration
EMPLOyERS' LIABILITY Number Dal@ Oale
Coveraao limit.
WORKERS' COMPENSATION STA TUTORY ~ a- iea onl in the tollowlnlJ states:
eMPLOYERS' BODILY INJURY BY ACCIUti:.NT Tl EACH ACCIDENT
LIABILITY BODILY INJURY ev OI$EASE I EACH EMPLOYEE
BODILY INJURY ~y DISEASE $ POLICY LIMIT
AUTOM081Li UABIUTY Policy tHrectivc ExpiTiilioil
Numbor 048912427 Dale 7/23/08 Data 7/23/09
Covllrs e Be..l. 1..,1""lts
o ANY AUTO X OWNED AUTOS HIRED AUTOS Comblnod SlnglQ limit of UllblUty
BODILY INJURY &. PROPERTY DAMAGE I $ 1 000 000 I EACH ACCID~NT
C] SpeCIFIED AllTO$ NON-OWNEO AUTOS Slit Liablll L.lmlts
Bodil In.u Pro DlmlKle Each
o OWNeo PRIVATE PASSENGER AUTOS I PERSON
n OWNED AllTOS OTHER THAN PRIvATE PASSENGER . . ACCIDENT
UMSFtELLA UABIUTY POlicy Eff~<;tIve ExpiriiltiOI'l
Number Dato Date
EACH OCCURRENCE GENERALAGG~eGATe I PRODUCTS. COMPLETED OPERATIONS AGGREGATE
$ I $
OTHER (Show Policy Effective Expiration
tvnA of Policy) Number Dato Dal.
OESCRIPTIO~ QFOPEM110"'8iloCA"'ONSNE",'C.es(R~STRICTIONSispeCIALIT";'$ . . .. .. ............ .... ...
Collier County Board of Com~. ers 7
~ r"
CANCELLATION V~~hA ,..} M
~~ Number of dilYs notice 00 ---- cl 7/30/10
V -AulhorfzOd Representative l Date
Sho\Jld i1ny 01 Ulo!l alXwe described polities be cancelled bafore the explratlon d:lte, the issuing COmpany will enaeallo'No.." ail within the number of days AfIIEt~!j above. written
notice to the cenlrieate holder nernea aDOve. Bvt failure to mailsucn notice shall imnO$e no oblioation or liabllltv of an" kind unOI'l me comn,gn" Its ~acnta or reDn!'sontativos.
U10523-2
~ 7/30/2010 15:06
Lion Insurance
LION INSURANCE COMPANY..COLLIER COUNTY
1/1
CERTIFICATE OF LIABILITY INSURANCE D,"
7/30/2010
Producer: Lion Insurance Company This Certificate Is ISSUfld as a matter of Information onlv and confers no rights
2739 u.s. Highway 19 N. upon the CerUflcate Holder. This Certificate does not amend, extend or alter
the coverage afforded by tfIe policies below.
Holiday, FL 34691
Insurers Affording Coverage NAIC #
Insured: South East Personnel Leasing, Inc. Insurer A: Lion Insurance Company 11075
2739 U.S. Highway 19 N. Insurer B:
Holiday, FL 34691 Insurer c:
Insurer 0:
Insurer E:
Coverages
The policies of Insurance listed below have been Issued to the insured named above for too policy period indicated Notwithstanding any requiramem, term or condio on of any contract or other document with respect to which
&11$ certificate may be Issued or may pertain, the inSLSance affordod by the policl8S described horein IS scJbJectto Blithe terms. (l~clu~ions. and cordltlons or such poic,es Aggregate IImlls shown may have been reduced by
paid claims
INSR AODL Type of Insurance Policy Number Policy Effective Policy Expiration Dale Limits
LTR INSRD Date
(MMIDDIYY) (M MIDDIYY)
~NERAL LIABILITY Each Occurrence
_ :immerCial General Liability Damage to rented premises (EA
_ Claims Made 0 Occur occurrence)
- MedExp
- Personal Adv Injury
General aggregate limit applies per:
:J Policy 0 Project 0 LOC GenerOlIAggregate
Products - Comp/Op Agg
AUTOMOBILE LIABILITY ComtllnedSinglelimlt
- Any AUIO (EAAcc,dent)
- Allo.....nedAu!os Bodi", Injury
- (f-'erPerson)
ScheduledAUlos
- HlredAUlo5 Bodit,ilniury
- Non.O....nedAulo5 (Per Accident)
- ProperryDamage
(Per Accident)
EXCESS/UMBRELLA LIABILITY Each Occurrence
=J~'m DClaimsM8de Aggregate
Deductible
A Workers Compensation and WC 71949 01/0112010 01/0112011 x I':'CStatu- I I ~~H-
Employers' L1abUly to"'Limits
A11y proprietorfpelttner/execulive officer/member E.l. Each Accident $1,000,000
excluded? E.l. Disease - Ea Employee $1,000,000
If Yes, describe under special previsions below. E.L. Disease- Policy Lirrits $1,000.000
Other Lion Insurance Company is A.M. Best Company rated A~ (Excellent). AHB # 12616
Descriptions of OperatlonsJLocatlonsNehlcles/Excluslons added by Endorsement/Special Provisions: ClientID: 41-65-750
Coverage only applies to acbve employee(s) of South East Personnel Leasing, Inc. that are leased to the following "Client Company":
B.Q. Concrete, L.L.C.
Coverage only applies to injuries incLfred by South East Persomel Leasing, Inc. active employee(s) , while working in Aorida.
Coverage does not apply to statutory employee(s) or independent contractor(s) of the Client Company or any other entity.
A list of the active employee(s) leased to the Client Company can be obtained by faxing a request to (727) 937-2138 or by calling (727) 938-5562.
Project Name:
FAX: 239-594-5351 & 239-252-6597 tiSSUE 07-30-10 (CF)
Be In Date: 3/29 2007
CERTIFICATE HOLDER CANCELLATION
COLliER COUNTY BOARD OF COUNTY COMMISSIONERS Should any ot t!1e abovedescribedpol,ciesbe cancelled before the expira tlondatetharaof,theissulnomsurar....ill
erdeavDrtoma,I30daysmittennotICetothecertificataholdernamedlolhelaft,butfailuretOdo 50 shall Imposa no
obligation orll1lbility ot aoyklnd upon the insurar. its 1lganls or ra presenla!iyes
3301 TAMIAMI TRAIL EAST ~ --/~
NAPLES, FL 34109
Patricia L. Morgan
From:
Sent:
To:
Cc:
Subject:
Attachments:
DeLeon Diana [DianaDeLeon@colliergov.net]
Friday, September 17,20109:20 AM
Patricia L. Morgan
Tibbetts, Rhonda; AtkinsonDayne
10-5518 Designated Driveways for Solid Waste
10-5518 Amend #1 (NR Contractors).pdf; 10-5518 Amend #1 (Sa Concrete).pdf; 10-5518
Amend #1 (Neubert).pdf
Pat,
Please attach the amendments to the contracts.
Thanks,
Diana De Leon
Purchasing Dept
(239)252-8375
Under Florida Law, e.mail addresses are public records, If you do not want your e.mail address released in response to a public records request, do not send
electronic mail to this entity, Instead, contact this office by telephone or in writing,
EXHIBIT A-I Contract Amendment #1
10-5518 "Designated Driveways for Solid Waste"
This amendment, dated ~ , ~ , 2010 ta the referenced agreement shall be by and
between the parties ta the ariginal A eement, B.Q. Cancrete, LLC (ta be referred ta as "Cantractar") and
Callier Caunty, Flarida, (ta be referred ta as "Owner").
Statement of Understanding
RE: Cantract # 10-5518 "Designated Driveways far Sa lid Waste"
The fallawing change ta the abave referenced Agreement has been mutually agreed to by the Cantractor
and the County. The additions ta the existing language in the Agreement are shawn herein by underlining;
deletians fram the Agreement are shown by strikethraughs.
Section 1 COMMENCEMENT shall be amended as fallaws:
The cantract shall be far a ane (1) year periad, cammencing an July 27,2010, and terminating July
26, 2011, ar aatil sHeh time as all 01::Kstaaamg Werk Orders iSS1:Iea flrier te the eJC13iratiaB of the
f.gTeemelrt periEla have beeR eompleteEl. This eaatFaet shall have eae aaditiElRal, efte (1) year
reRawa!, reaewable aflal:lally. The Caunty Manager, ar his designee, may, at his discretian, extend
the Agreement under all af the terms and canditians contained in this Agreement far up ta ane
hundred eighty (1-80) days. TheCauntY!\.1anager, aihisdesignee, shall give theCantractarwritten
natice of the Caunty's intentian ta extend the Agreement term nat less than ten (10) days priar ta
the end afthe Agreement tenH then ia effeet.
Section 2 STATEMENT OF WORK, delete and replace paragraph 2 and 3:
Priar ta the issuer-we af a Work Order, the Camlty skall pravide a sHfflffiary of Wark t<3 be petfermed
'l.'hich 'will affara the CeFltraetor the oflfwrtunity ta submit a formal ql:latation far the 'Nark; the
COBtraetor shall. fespElRd with the informatian S01:lgRt v.<ithia seveR (7) \varkiag aays. Far 13rajeets
with an estimated east of Fifty ThEll:lsaRd Dollars ($5(,),990) Elr less, the CElaRfy shall abtaiR a pr<lposal
from ElFIe afthe aWafaed ContFaetar(s), Regatiate favorable project terms and eaRditiaRs, and issue a
Work Order, sigBod by the Depar..ment Directar ta iaitiate the projeets.
Far projeets 'Nit-h aa estimated east over Fifty Tholisaad Dallars ($50,000) aHd less thafl One HI:lFlared
Thausand Dallars ($100,000), the department shall El\iote a1:lt the wark amang all aViardcd
COBtractor(s), or eampetitively salieit for He".... qliete. The Contractar shall respaHd with the
information salight withia ton (10) warking days. The Cauat)' ..viII aegotiate fa'iarable project terms
and eaaditioas, aHd issl:le a Work Order, sigaed by the Departmeat Din~ctor and Divisian
,^.dmiaistratar ta initiate the projects.
Far purchases estimated ta be less than $50,000 per arder: the department may select ane of the
awarded Cantractor(s), quate aut the work among all awarded Cantractar<s), ar campetitively salicit
far new quotes.
. Far purchases estimated ta be greater than $50,000 per order and less than $100.000 per order:
the department may quate aut wark among the awarded Contractor(s). ar, may conduct a separate
new solicitation.
. The Caunty will generally use a purchasing card for the arder pracess ar a County purchase
order.
Section 29 COMPONENT PARTS OF TIllS CONTRACT shall be amended as fallaws:
This Cantract cansists af the attached ar referenced companent parts, all af which are as fully a part
af the Agreement as if herein set aut verbatim, including: Cantractar's Prapasal, Insurance
Certificate, ITB Na. 10-5518, any addenda, any Purchase Order Q\:letatien/Work Oraer made or
issued pursuant to this Agreement, and any related plans ar specificatians far any such Q1:Iatations or
Wark OnlersPurchase Order.
Hourly Rates (Attached as Schedule A) shall be added ta the cantract.
All other terms and conditians afthe agreement shall remain in farce.
Schedule A
Hourlv Rates
Superintendent
Carpenter/Concrete-Finisher
Carpenter/Concrete~Laborer
$50.00/hour
$30,OO/hour
$15.00/hour
Percentage Mark-Up on Parts and Materials
Percentage Mark-Up on Subcontracted Work
15%
10%
IN WITNESS WHEREOF, the Consultant and the County bave each, respectively, by an authorized
person or agent, hereunder set their hands and seals on the date(s) indicated below.
CONTRACTOR:
B.Q. Co.crete, LLC
Accepted: ,s-;. ;-f I ~ , 20 I 0
OWNER:
~DIRECTOR
By: ~. G/Il1J
Stephen Y. C
CONTRACT TECHNICIAN
By _ ~-I.OQ
Diana- Leon