#09-5219 (Design-Build Engineers & Contractors)
A G R E E MEN T 09-5219
for
Annual Contract for Bridae Repairs and Maintenance
THIS AGREEMENT is made and entered into this q~ day of Fe..~~ ,2010, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner") and Design Build Engineers &
Contractors, Corp. (DBE&C), authorized to do business in the State of Florida, whose business
address is 801 North Magnolia Avenue, Suite 406, Orlando, Florida 32803 (hereinafter referred to as
the "Contractor").
WIT N E SSE T H:
1. COMMENCEMENT: The contract shall be for a one (1) year period, commencing on
"'Fe1n. q ,2010, and terminating Fe. b -R ,2011, or until such time as all
outstanding Work Orders issued prior to the expiration of the Agreement period have been
completed. Additionally, by mutual agreement and funding availability, this contract shall have
three additional, one (1) year renewals, renewable annually. The County Manager, or his
designee, may, at his discretion, extend the Agreement under all of the terms and conditions
contained in this Agreement for up to one hundred eighty (180) days. The County Manager, or his
designee, shall give the Contractor written notice of the County's intention to extend the
Agreement term not less than ten (10) days prior to the end of the Agreement term then in effect.
2. STATEMENT OF WORK: The Board of County Commissioners deemed three (3) firms to be pre-
qualified and awarded a Contract to each firm. Each awardee will enter into an Agreement to
provide complete services for bridge repairs and maintenance on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP# 09-5219 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement. The execution of this Agreement shall not be a commitment to the Contractor that
any work will be awarded to the Contractor. Rather, this Agreement governs the rights and
obligation of the Quotation procedure outlined in the next paragraphs and all Work undertaken by
Contractor for Owner pursuant to this Agreement and that procedure during the term and any
extension of the term of this Agreement.
Prior to the issuance of a Work Order, for projects with an estimated cost up to Two Hundred
Thousand Dollars ($200,000) or less, the Owner shall get written quotations from the three (3)
selected firms. The Contractor shall respond with the information sought within seven (7) working
days. The County will negotiate favorable project terms and conditions, and issue a numbered
Work Order to initiate the projects. If a Performance Bond is required, the Contractor shall provide
within seven (7) working days after notification of award.
For projects over Two Hundred Thousand Dollars ($200,000) and less than Seven Hundred Fifty
. Thousand Dollars ($750,000), competitive quotations shall be solicited from three (3) firms. The
Contractor shall respond with the information sought within seven (7) working days. When a
Performance Bond is required, the Contractor shall provide within seven (7) working days after
notification of award. The County will negotiate favorable project terms and conditions. Staff
recommendations will then be submitted to the County Attorney and Board of County
Commissioners for approval.
Page -1-
In each Request for Quotation, the Owner reserves the right to specify the period of completion
and the collection of liquidated damages in the event of late completion.
3. THE CONTRACT SUM: The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation. Any County agency may utilize the services offered under this contract, provided
sufficient funds are included in its budget(s).
4. NOTICES: All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
Design Build Engineers & Contractors, Corp. (DBE&C)
1801 S. Perimeter Road, Suite 160, Ft. Lauderdale, FL 33309
954-771-8705 telephone
954-771-8707 fax
Michael A. Thompson, MSc, CGC, PE, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Collier County Government Complex
Purchasing Department
3301 East Tamiami Trail
Purchasing Building G
Naples, Florida 34112
Attention: Stephen Y. Carnell
Purchasing/General Services Director
Phone: 239-252-8371
Fax: 239-252-6584
I
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP: Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES: In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Contractor shall pay all sales,
Page -2-
consumer, use and other similar taxes associated with the Work or portions thereof, which are
applicable during the performance of the Work.
7. NO IMPROPER USE: The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Contract of the Contractor. Should the Contractor fail to correct any
such violation, conduct, or practice to the satisfaction of the County within twenty-four (24) hours
after receiving notice of such violation, conduct, or practice, such suspension to continue until the
violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION: Should the Contractor be found to have failed to perform his services in a
manner satisfactory to the County and requirements of this Agreement, the County may terminate
said Agreement for cause; further the County may terminate this Agreement for convenience with
a seven (7) day written notice. The County shall be sole judge of non-performance.
9. NO DISCRIMINATION: The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
10. INSURANCE: The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $2,000,000 Per
Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liabilitv: Coverage shall have minimum limits of $2,000,000 Per
Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability.
This shall include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-
Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of $500,000 for each occurrence including Protection and
Indemnity including crew with a minimum limit of $1,000,000 per each occurrence, if
applicable.
D. United States Lonashoreman's and Harborworker's Act coverage shall be maintained
where applicable to the completion of the work.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained by
Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County thirty (30) days prior to any expiration date. There shall be a thirty (30) day notification to
the County in the event of cancellation or modification of any stipulated insurance coverage.
Page -3-
Contractor shall insure that all subcontractors comply with the same insurance requirements that
he is required to meet. The same Contractor shall provide County with certificates of insurance
meeting the required insurance provisions.
11.INDEMNIFICATION: To the maximum extent permitted by Florida law, the
ContractorNendor/Consultant shall indemnify and hold harmless Collier County, its officers and
employees from any and all liabilities, damages, losses and costs, including, but not limited to,
reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence,
recklessness, or intentionally wrongful conduct of the ContractorNendor/Consultant or anyone
employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement.
This indemnification obligation shall not be construed to negate, abridge or reduce any other rights
or remedies which otherwise may be available to an indemnified party or person described in this
paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be required to
provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment Bond
prior to commencing performance, for the full amount of the Work, which shall act as a security
guaranteeing the performance of the Contractor's work and the payment by the Contractor to
any other party (ies) providing labor and/or materials in connection with each construction or
renovation project performed by the Contractor. The bonds shall be furnished using the forms
prescribed in Exhibit "A".
C. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its
right to do business in the State of Florida, or it ceases to meet the requirements imposed by
the Contract Documents, the Contractor shall, within five (5) calendar days thereafter,
substitute another bond and surety, both of which shall be subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit "C".
14.PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any payments
otherwise due Contractor under this Agreement or any other agreement between Owner and
Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss
because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence
indicating probable fling of such claims; (c) failure of Contractor to make payment properly to
subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be
completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work
will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the
Contractor; or (g) any other material breach of the Contract Documents.
Page -4-
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any sums
due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner,
whether relating to or arising out of this Agreement or any other agreement between Contractor
and Owner.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from specifications
shall be approved in writing by Owner in advance.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of
the change. Except in an emergency endangering life or property, or as expressly set forth
herein, no addition or changes to the Work shall be made except upon written order of Owner, and
Owner shall not be liable to the Contractor for any increased compensation without such written
order. No officer, employee or agent of Owner is authorized to direct any extra or changed work
orally. Any modifications to this Contract shall be in compliance with the County Purchasing Policy
and Administrative Procedures in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an agreement is reached between Contractor and Owner concerning the
requested changes. Contractor shall promptly perform changes authorized by duly executed
Page -5-
Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change order
in the manner as Owner and Contractor shall mutually agree.
18. COMPLIANCE WITH LAWS. Contractor agrees to comply, at its own expense, with all federal,
state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable
to the Project, including but not limited to those dealing with taxation, workers' compensation,
equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553,
Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it
shall promptly notify Owner in writing.
19. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and
waste materials arising out of the Work. At the completion of the Work, Contractor shall remove
all debris, rubbish and waste materials from and about the Project site, as well as all tools,
appliances, construction equipment and machinery and surplus materials, and shall leave the
Project site clean and ready for occupancy by Owner.
20. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior
consent in writing of Owner. If Contractor does, with approval, assign this Agreement or any part
thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the
obligations and responsibilities that Contractor has assumed toward Owner.
21. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or fixtures to
be incorporated into the Project. Contractor warrants to Owner that any materials and equipment
furnished under the Contract Documents shall be new unless otherwise specified, and that all
Work shall be of good quality, free from all defects and in conformance with the Contract
Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement or
repair. These warranties are in addition to those implied warranties to which Owner is entitled as
a matter of law.
22.STANDARDS OF CONDUCT: PROJECT MANAGER. SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed and
courteous. Subject to the American with Disabilities Act, Contractor shall supply competent
employees who are physically capable of performing their employment duties. The County may
require the Contractor to remove an employee it deems careless, incompetent, insubordinate or
otherwise objectionable and whose continued employment on Collier County projects is not in the
best interest of the County.
23. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or
regulations of any public authority having jurisdiction over the Project requires any portion of the
Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility
Page -6-
therefore, pay all costs in connection therewith and furnish to the Owner the required certificates
of inspection, testing or approval. All inspections, tests or approvals shall be performed in a
manner and by organizations acceptable to the Owner.
24. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
25. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or
the Work or property at the Project site or adjacent thereto, Contractor, without special instruction
or authorization from Owner is obligated to act to prevent threatened damage, injury or loss.
Contractor shall give the Owner written notice within forty-eight (48) hours after the occurrence of
the emergency, if Contractor believes that any significant changes in the Work or variations from
the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations.
If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the
Contract Amount or an extension to the Contract Time.
26. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is
ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such
designated portion) is substantially complete and request that Owner issue a Certificate of
Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall make
an inspection of the Work (or designated portion thereof) to determine the status of completion. If
Owner does not consider the Work (or designated portion) substantially complete, the Owner shall
notify Contractor in writing giving the reasons therefore.
If Owner considers the Work (or designated portion) substantially complete, Owner shall prepare
and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall fix the date
of Substantial Completion for the entire Work (or designated portion thereof) and include a
tentative punchlist of items to be completed or corrected by Contractor before final payment.
Owner shall have the right to exclude Contractor from the Work and Project site (or designated
Page -7-
portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance with
the Contract Documents and is ready for final inspection and acceptance, Owner will make such
inspection and, if Owner finds the Work acceptable and fully performed under the Contract
Documents, he shall promptly issue a Certificate of Final Completion, Exhibit F, recommending
that on the basis of his observations and inspections, and the Contractor's certification that the
Work has been completed in accordance with the terms and conditions of the Contract
Documents, that the entire balance found to be due Contractor is due and payable. Final payment
shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit "B".
(2) Consent of Surety (if applicable) to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to the
acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment
shall not become due and payable.
27 . LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5) calendar
days from the Commencement Date. No Work shall be performed at the Project site prior to the
Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall
be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for Quotation.
The date of substantial completion of the Work (or designated portions thereof) is the date
certified by the Owner when construction is sufficiently complete, in accordance with the Contract
Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use
for which it is intended. The Work shall reach final completion and be ready for final acceptance
by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete the
Work within the specified time period, Owner shall be entitled to assess as liquidated damages,
but not as a penalty, the amount specified in the Request for Quotation for each calendar day
thereafter until substantial completion is achieved.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly
waives and relinquishes any right which it may have to seek characterize the above noted
liquidated damages as a penalty, which the parties agree represents a fair and reasonable
estimate of the Owner's actual damages at the time of contracting if Contractor fails to
substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first day
and include the last day of such period. If the last day of any such period falls on a Saturday or
Page -8-
Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall
be omitted from the computation, and the last day shall become the next succeeding day which is
not a Saturday, Sunday or legal holiday.
28. CONTRACT ADMINISTRATION. This Agreement shall be administered on behalf of the County
by the Transportation Engineering and Construction Management Department.
29. COMPONENT PARTS OF THIS CONTRACT. This Contract consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set out
verbatim, including: Contractor's Proposal, Insurance Certificate, RFP No. 09-5219, any addenda,
any QuotationlWork Order made or issued pursuant to this Agreement, and any related plans or
specifications for any such Quotations or Work Orders.
30. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or
give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any
County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics
Ordinance No. 2004-05, and County Administrative Procedure 5311. Violation of this provision
may result in one or more of the following consequences: a. Prohibition by the individual, firm,
and/or any employee of the firm from contact with County staff for a specified period of time; b.
Prohibition by the individual and/or firm from doing business with the County for a specified period
of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate
termination of any contract held by the individual and/or firm for cause.
31. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
32. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. No
markup shall be applied to sales tax.
33.IMMIGRATION LAW COMPLIANCE: By executing and entering into this agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible for
complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8
U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the
Contractor to comply with the laws referenced herein shall constitute a breach of this agreement
and the County shall have the discretion to unilaterally terminate this agreement immediately.
34. VENUE: Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
35.0FFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES: Collier County encourages and
agrees to the successful proposer extending the pricing, terms and conditions of this solicitation or
resultant contract to other governmental entities at the discretion of the successful proposer.
36.AGREEMENT TERMS: If any portion of this Agreement is held to be void, invalid, or otherwise
unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect.
Page -9-
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an authorized
person or agent, hereunder set their hands and seals on the date and year first above written.
ATTEST: " _,
Dwight E. ,~:1'6ck, Clerk of Courts
~!v
~A-o OA-A.JG
Type/Print Witness Name
Approved as to form and
le~cienl?
- - J~/L
A. ltounVf Attorney
~'7
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
'-1_ ~ w. ~
By: -ru-<<-
Fred W. Coyle, Chairman
Design Build Engineers & C tractors, Corp (DBE&C)
Contractor
By:
Signature
~ \ Co "'-t>. e- (.., ,. ~'O k.i S':>0
Typed Signature
f 1te-c;(v~1
Title
Page -10-
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 09-5219
KNOW ALL MEN BY THESE PRESENTS: That
, as
Principal, and , as Surety, located at _
(Business Address)
are held and firmly bound to as
Oblige in the sum of ($) for
the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors
and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the
,20_, with Oblige for
day of
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this _ day of
20_, the name of under-signed representative, pursuant to authority of its governing body.
Page -11-
Signed, sealed and delivered
in the presence of:
PRINCIPAL:
By:
Name:
Its:
Witnesses as to Principal
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of
,as cl
corporation, on behalf of the corporation. He/she is personally
as identification and did (did
20_, by_
,a
known to me OR has produced
not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
ATTEST:
SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
Page -12-
Witnesses
As Attorney in Fact
(Attach Power of Attorney)
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20___, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
(AFFIX OFFICIAL SEAL)
Name:
(Legibly Printed)
Notary Public, State of
Commission No.:
Page -13-
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 09-5219
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address) are held and firmly bound to
, as Oblige in the sum of
($ ) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the
20_, with Oblige for
day of
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page -14-
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
20_, the name of each party being affixed and these presents duly signed by its
undersigned representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of :
PRINCIPAL:
Witnesses as to Principal
By:
Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this _ day of
200_, by ,as of
, a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
(AFFIX OFFICIAL SEAL)
Name:
(Legibly Printed)
Notary Public, State of
Commission No.:
Page -15-
ATTEST:
SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
Witnesses
As Attorney in Fact
(Attach Power of Attorney)
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20___, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
(AFFIX OFFICIAL SEAL)
Name:
(Legibly Printed)
Notary Public, State of
Commission No.:
Page -16-
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and its
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and Owner, dated
20_ for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted against the Owner arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS:
President
DATE:
Witnesses
[Corporate Seal]
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20_, by , as of
, a corporation, on behalf of the corporation. He/she is
personally known to me or has produced as
identification and did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commissioner No.:
Page -17-
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager)
(County Department)
Collier County Board of County Commissioners (the OWNER) or
Collier County Water-Sewer District (the OWNER)
FROM:
(Contractor's Representative)
(Contractor's Name)
(Contractor's Address)
RE:
Name)
Contract No. 09-5219
Project No.
Application Date
Payment Application No.
for Work accomplished through the Date:
(Project
Original Contract Time:
Revised Contract Time:
Retainage @ 10% thru[insert date] $
Retainage @ _% after [insert date] $
Percent Work completed to Date:
Percent Contract Time completed to Date
%
%
Liquidated Damages to be Accrued $
Original Contract Amount: $
Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
and stored to Date $
Less previous payment (s) $
AMOUNT DUE THIS
APPLICATION: $
ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through _ inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have
been paid for work which previous payments were issued and received from the OWNER and that current payment is now
due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added
to the revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR:
DATE:
(Contractor's Name)
(Signature)
(Type Name & Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
By Design Professional:
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
(DP's Name)
(Signature) DATE:
(Type Name & Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager:
Page -18-
(Signature) DATE:
(Type Name and Title)
EXHIBIT D
CHANGE ORDER
CHANGE ORDER NO.
CONTRACT NO. 09-5219
TO:
DATE:
PROJECT NAME:
PROJECT NO.:
Under our AGREEMENT dated
,20 .
You hereby are authorized and directed to make the following change(s) in accordance with terms and conditions
of the Agreement:
FOR THE (Additive) (Deductive)
Sum of: $
($
Original Agreement Amount $
Sum of Previous Changes $
This Change Order (Add) (Deduct) $
Present Agreement Amount $
The time for completion shall be (increased/decreased) by calendar days due to this Change Order. Accordingly,
the Contract Time is now ~ calendar days. The substantial completion date is and the
final completion date is . Your acceptance of this Change Order shall constitute a modification to our
Agreement and will be performed subject to all the same terms and conditions as contained in our Agreement indicated above,
as fully as if the same were repeated in this acceptance. The adjustment, if any, to the Agreement shall constitute a full and
final settlement of any and all claims of the Contractor arising out of or related to the change set forth herein, including claims
for impact and delay costs.
Accepted:
,20
CONTRACTOR:
OWNER:
BOARD OF COUNTY COMMISSIONERS
OF COLLIER COUNTY, FLORIDA
By:
By:
DESIGN PROFESSIONAL:
By:
Page -19-
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No.
ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -20-
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on
,20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
,20_
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
,20_
OWNER
By:
Type Name and Title
Page -21-
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No.
PROJECT:
ENGINEER'S Project No.
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page -22-
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on
,20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
Page -23-
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
.....
CONTRACTOR
BY:
Attest:
Page -24-
~
ACORD@)
~
CERTIFICATE OF LIABILITY INSURANCE
PRODUCER (407)884-7843 FAX: (407)884-6014
C F Insurance Services, Inc.
P.O. Box 1189
DATE (MtNDDIYYYY)
3/11/2010
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND,EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Apopka
INSURED .
Design Build Engineers & Contractors
801 N. Magno~ia Ste. 406
INSURERS AFFORDING COVERAGE
I~URERA,Mid Continent Casualty
INSURER 6: progressive Express Insurance
INSURERC:Commerce &. Industry Insurance
INSURER D:
NAIC#
23418
10193
Orlando I FL 32803
COVERAGES
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. N01W1THSTANDlNG
ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESpECT TO WHICH THIS CERTIFICATE MAYBE ISSUED OR
MAY PERTAIN THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO All THE TERMS, EXCLUSIONS AND CONDITIONS OI5UCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. .
INSR DO' POLICY NUMBER POLICY ~FECTlVE UMITS
GENERAL UAIlILlTY
X COMMERCIAL GENERAL. liABILITY
A X CLAIMS MADE [iJOCCUR' 4GL000773476
FL 32704-1189
.Arff AUTO
B I ALL O'MolEO AUTOS r"""H
X SCHEOULED.AUTOS .
HIRED AUTOS
NON-OWNED AUTOS
I
GARAGE LIABILITY
ANY AUTO.
C EXCESS I UMBRELLA UABlUTY
X OCCUR o CLAIMS MADE B0086453180
EACH OCCURRENCE 1 000 000
PREMIS a occurrence S 10 000
MEDEXP (Any. one person) S Excluded
PERSONAL & ADVINJURY S 1000000
GENERAL AGGREGATE $ 2,000 000
PRODUCTS -COMPIOP AGG $ 2000 000
COMBINED SINGLE LIMIT
(Eo ac:ddent)
s
1,000,000
60DIL Y INJURY
.(por parson)
BODilY INJURY.
(Per accident)
PROPERTY DAMAGE
(Per accident)
AUTO ONLY - EA ACCIDENT
s
S
$
1 000 000
s 1 000 000
S
OTHER THAN
AUTO ONLY:
EA ACC
AGG
EACH OCCURRENCE
02/08/2010 11/2/2010 I AGGREGATE
DEDUCTIBLE
RETENTION $
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY Y I N
ANY. PROPRIETORIPARTNERlEXEClJTJVE D .
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
~~I~t.~~~~6'NS below
I OTHER
E.L. DISEASE - EA EMPLOYEE $
E.L DISEASE. POLrCY LIMIT. S
DESCRIPTION OF OPERA nONS I LOCA llONS I VEHICLES I EXCLUSIONS A ODED ElY ENDDRSE:MENT I SPECIAL PROVISIONS
Collier COunty. Board of. County Commissioners islist~d as Additional In*ured. Annual Contraet for Bridge Repairs'
Maintenance.
CERTIFICATE HOLDER
CANCELLATION
Collier
3301 E.
Naples,
brendareaves@colliergulf.n
County BOCC
Tamiami Trail
FL 34112
SHOULD ANY OF THE AElOVE DESCRl8ED POLICIES ElE CANCELlED BEFORE THE EXPIRATION
DATE niEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL ~ DAYS WRITTEN.
NOllCE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL
IMPOSE N006L1GAllON OR LIABJUTY OF ANY KiND UPON THE INSURER,ITS AGENTS OR
REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE
Jon DeClue/JENN
ACORD 25 (2009/01)
fNSD25 (200901)
~..4C -- ~/""...c'
@ 1988-2009 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD
.,. "' 3/1112010 14:06
. :-
. .. .
. )I
Lion Insurance
LION INSUR~NCE CONPAHY~DESIGN BUILD. ENG I COLLIER ~O
1/1
,JrocIucer: .'
Lion Insurance COmpany
2739 U.S. Highway 19 N.
I-k?liday, ~ 34691
CERTIFICATE OF' LIABIUTY INSURANCE
TII" Cerull..... .. __ . . ....tau' ot In'_tl". emlv and -r... IlO rllJhr.
upon.IM Certlfkalll ttDIcf<<. T" ~1II__1IOt a_"- atoM ..nl...
tY ....-. ,!folded by ~ poIld_ "'Ivw.
Insl.l'~ AIfordnIJ CoVeraQe
u.n bun.... ~I'I\'
CoIo
3/UQ010
Insured:
SoUth Easf Pe1'8onnel Leasing, Inc.
2739 U.S: Highw8Y'19 N.
Holiday, F1: 34691
....., Ie
lno.... IS:
InouNr c:
InsInr D:
btnr E:.
NAlC",
11075
Coverages . .. ,. . .
. _ b__....._ ....perlOCl....~. 1lV_~tIIlIIl._or_I"al.nv-" -
.,.,,_ ....,""~CVlN'fpolllli".lIIoin.......oI!"r"""trVNpokiH_rI>H _.1.....,..,....11Io......., _'?"I.IfllICllIIlIIons al_polIlSoI. AWWlJIII- -1IlI\'- __db(
pMldeirll. . ' " . . . .'
INSR ,t,CDI.
LTR ~
Type of InsurInce
Poley NlIl'lber
~ J;ffKl!w
, DU .
CMMlDDNYJ
.PIlley ElCphlIon D.. .
, '(M'MJODIVY)
Urnts
tH NERAL UABlUTY .
~ p,ommercIal Gcin~ Uabiity. .
... ~ Claims Made O' 0Ccl.r
-
..... .
General aQlJregBta fi.,lit apples per: .
:JPoI~ D~ ,0 LOC,".
A,(ITOIlOBlLE 'uAsuTv
- ~ "'*'
- AI~~.
- ScI*uIod_.
. - Itrtd AleC
~ Non.OWnod",*",
-
Each 0<cImnce
~ to ,_Il'tft'lho lEA
'DCD..I'nrD)
'.
-ElqI
PellOlllllAdv IiIJuIy .
_Aotw"OlIl.
p,_- COrrflIOp AfIlI
e_InodSll)glo UmiI
(C1I./lCclOMl
1IocI1t,t1r$ly
tp-"-rtG\)
llodlf~)ay .
11'_ A<cidIiitl
P~CIIriIge
(Per ,'Icddeoll
EXCESSlUIlIBRELLA UA81UTY'
,.~... '00--
40._ .
Ee<h Occur-.o
~.
A
WOl1C~ Compensation and
EmpIoyen' I.Iabllly . , .
Nrr~;~IIln~/IXICIAM:oi'lic~.r
.........n '. '
IfYe.~ detcribe ~der sP.cw p......;l~ b.-Iaw. :
we 71949
01J01f.Z010
0110112011 '
xT~= T . r~~
E.L. Each Acddant ,"'000,000
I5.L. Dloonc. Ea Empl"",. . Sl.DOO.GOO
'E.L. Dlaue. - Pilley UniIII'. ' $I.DOO,OIllI .
0Ihllr . Uon Insurance ComDMY rs A.M....t ComlNmY ret~ A- (Exctlleiatl. AM. # 12616
C.SC~1l Of OperationclLocltlonsNel\lclesl!xclu.lonll added by I!ndarsaIlW1t1Spec:lal Provl,Jons: . . , Cient IJ): 1Il-!lH02
COverage only lIPPl~ to actlve employee(s) of sOuth ElISt 1"ersoMel L.e8Slng, Inc. that ... .Ie~ed to IIle fo/Iowing .Clent ~y":
. .:'. '. : .. Deslgn.8uildEngineena.contracto,,4;orp." . . . ..'
Coyerage only applies to ini\.l1es IncllTed by South East I'ersomel Leasing, lnc. 'actlw emploYee(s) .' ,while worldnll In l'lDl1dil.
Coverllge ~es not apply to stBt.utory ~(s) or lildepland.,t'tontri.ctar{s) of the Client Compeoy or.any oth~r entity,
A list of the. active ~oyee(s) leased to the Client coirpq can blfobtalned ~ taldng a ~ to (n7) m-2138 or by cllllng (727) 938-5562.
Project Nem.: "'fOR SIl) PU.RPOSES ONLY.' CONTRACT - Annual contract foi' bridge .;.plllrs .. mafn~.nca, Collar COU'ltv, Rorida
FAX: <407-6e108411SSUE: 03-1 1-10 (CF) '.
......... Data: 2/512007
CEInPICAll!~
CPlllER COUNTY BOARD OF COUNTY COMMISSIONERS,
33Cll E. TAMIAMI TRAIL
NllPLES. Fl 34112
CANCELLATON
S"",*,....a/u... _~Q"g.lbo ..nc:eIod"""''''''~d''_.110 ,...."" w,.... .
."""_.....11 X!~._ft(lllc.lO u....___lD IhIIoft,btlralkl'." do SO _I i~..n.
'-""i"''''I~lIyal",,ldnd_''''-.i1r_.'''_''!"l'-' - . .'
:ah~__ .
,>-
Re:
DATE RECEIVED: t1v~
/'( trfYl yr-/f (~ ~
?l~ -t' ~ do
~~ ;~5.P1'
p~ 1
1 '.': . k
~ " ., ow
?SJ C t>.~~
ounty Attorney's Office ~ ~.~; _.~.
llention: Jeff Klatzkow '51< T bLu,~/qp-' .:tL
honda Cummings, FCCN, CPPB, Contract Specialist I' . () \ j:i A5
Purchasing Department, Extension 89413//111 D <r~ i5t\1 It
~~~n~':~:~ce~09-5219 "Annual Contract for Bridge Repairs:/ )} b) ) P
~~M
DO NOT WRITE ABOVE THIS LINE
-
ITE
ROUTED TO:
REQUEST FOR LEGAL SERVICES
arch 3, 2010
Contractors: Quality Enterprises
Walker Contracting Group
vDesign-Build Engineers and Contractors
BACKGROUND OF REQUEST:
This Contract was approved by the BCC on February 9, 2010, Agenda @
Item 16.B.7
This item has not been previously submitted.
ACTION REQUESTED:
Contract review and approval.
OTHER COMMENTS:
This is a standard contract with no changes. Please forward to BCC
for signature after approval. If there are any questions concerning the
document, please contact me. Purchasing would appreciate notification when
the documents exit your office. Thank you.
C: Marlene Messam, TECM
RECEIVED
MAR l 0 2010
PVRCHAc,nNA O;;P'T
RLS# In- P R-e- O/.jtJ3
CHECKLIST FOR REVIEWING CONTRACTS
B'"-ild ~I~eers l C"frHtors, COr(
:;::Yes No _::::::>
Yes No
::2.klL Exp. Date
'.1 Exp. Date
f MIL Exp. Date
1 MIL Exp. Date
'0 oeD Exp. Date
I
I t--{IL Exp Date
I t-1,\L Exp Date
II Exp Date
,I Exp Date
Entity Name: b't:.5'( j VI
Entity name correct on contract?
Entity registered with FL Sec. of State?
Insurance
Insurance Certificate attached?
Insured registered in Florida?
Contract # &lor Project referenced on Certificate?
Certificate Holder name correct (BCC)?
Commercial General Liability
General Aggregate Required $ ;;L H I L.
Products/CompVOp Required $
Personal & Advert Required $
Each Occurrence Required $
Fire/Prop Damage Required $
Automobile Liability
Bodily Inj & Prop Required $
Workers Compensation
Each accident Required $ ~ tv{ I L-
Disease Aggregate Required $
Disease Each Empl Required $
Umbrella Liability
Each Occurrence Provided $ ] "'" \ L
Aggregate Provided $ \l
Does Umbrella sufficiently cover any underinsured portion?
Professional Liability . \, ~
Each Occurrence Required $ l'-.l Provided $
Per Aggregate Required $ Provided $
Other Insurance "No AM/lo.(./Jr
Each Occur Type: US l,,<\?UrC"""'-Required $ G- l \J E J0 Provided $
aj f-\.-t-r~or.....: rlce,r Ad
County required to be named as additional insured?
County named as additional insured?
/ Yes
~Yes
Yes
Yes
Provided $
Provided $
Provided $
Provided $
Provided $
;).. MIL
~ MIL.
~ t-\ IL
Provided $
Provided $
Provided $
Provided $
Exp Date
Exp Date
Yes
"/Yes
* ~Yes
Indemnification
Does indemnification meet County standards?
Is County indemnifying other party?
/Yes
Yes
Performance Bond
Bond requirement referenced in contract?
Ifattached, expiration date of bond
Does dollar amount match contract?
Agent registered in Florida?
/Yes
Yes
Yes
Signature Blocks
Correct executor name in signature block?
Correct title of executor?
Executor authorized to sign for entity?
Proper number of witnesses/notary?
Authorization for executor to sign, if necessary:
Chairman's signature block?
Clerk's attestation signature block?
County Attorney's signature block?
_~"",-:y es
--'zYes
/Yes
---L- Y es
No
No
~~~~
Il
II
,.
,J.. / ;)..fv 111
'II III
II
"
11/.2/10
\I
No
Exp. Date
Exp. Date
NO
Exp Date
f
o tJ L~ Ll S:T t='",J)
OtJ Wlc
UiCTI F\ (.A- \ L
- ?
.
2
,
?
NO~
No ~ N v,.) Ic-:, T"s LL' 5'........ c e-
Ce..-t\f \cc-..+e, d-
No ~ \ \/.e...S ~tJesf:.~\.+06-
=ZNo f\-tDt'L~~>
No -
No
No
No
No
No
No
/Yes
~Yes
~Yes
Attachments
Are all required attachments included?
Yes
No
No
No
R:e~e~ Initials: ~
Dale: '3 (Ii )0
04-COA-0 03 /222
~\) e.)Lee ....+eJ
Uf\\. t-eJ.. BON as
tJ", "'" Gl ~~ ~"
~ ~'
~~ J-t-.)J ~ t:-~J
'"'In" rtvu:?D frU_m~t)tLc)),~~
-..,.. . u....~u...u. ~,.kLt~~...........
~ .. Q-'L l~d&>7 .. ~ "3~? D~
. J
-"_m ........ .,u.-(~'1.
-Pe~u~~g
-_.':;....~...,_.~~..~.............~."..
......."+.....nGe4ti~fuJ:?S ..
.l.~.n\ : '\ C:-,..~ ....~.. /I: 1_'~. J,
~.V'>-L .~ ~"Dt'J~'
'."..-.. ...... . ....kd~.~
3~ [ "C'" -Z \ , 1
.. .. h... ',. . ..., .. u . .Vi Y
, .i. '~'~.u4..
-)'y~'~T' ~L-3_Ltll';)._r .,
~~~~stt3..t.......t....~-
.<;..~. . II.
j
------'-~--------_._--_._~._._---._-_.._-_._-,..__._-
MEMORANDUM
TO:
Ray Carter
Risk Management Department
~
Ar~-(f
FROM: Rhonda Cummings, FCCN, CPPB, Contract Specialist
Purchasing Department
DATE: March 3, 2010
RE: Review of Insurance for Contract: #09-5219 "Annual Contract for
Bridge Repairs and Maintenance"
Contractors: Quality Enterprises
Walker Contracting Group
V'Design-Build Engineers and Contractors
This Contract was approved by the BCC on February 9, 2010, Agenda Item
16.B.7
Please review the Insurance Certificates for the above referenced contract. If
you have any questions, please contact me at extension 8941.
Thank you.
dod/RC
if ATE RECEIVED
!l 4 2010
RI SK h'<I'iAGEME
C: Marlene Messam, TECM
mausen_9
From:
Sent:
To:
Cc:
Subject:
RaymondCarter
Friday, March 05, 2010 2:20 PM
CummingsRhonda
MessamMarlene; mausen_g; DeLeonDiana; colli_m
Contract 09-5219 "Annual Contract for Bridge Repairs and Maintenance"
Rhonda I have approved the certificate(s) of insurance for contract 09-5219 provided by Design-Build Engineers and
Contractors. The contract will now be forwarded to the County Attorney's Office for review.
Marlene, please note that the contract does contain the clause "...United States Longshoreman's and Harborworker's
Act (USL&H); coverage shall be maintained where applicable to the completion of the work". Proof of USL&H was not
provided by the vendor so this may limit the type of work they can do under the contract. Please call me to discuss this
before giving any notice to proceed to the vendor under this contract.
Thank you,
Ray
~~
Manager Risk Finance
Office 239-252-8839
Cell 239-821-9370
Under Florida Law, e-mail addresses are public records. If you do not want your e-mail address released in response to a public records request, do not send
electronic mail to this entity. Instead, contact this office by telephone or in writing.
1
www.sunbiz.org - Department of State
..
Page 1 of2
Home
Contact Us
E-Filing Services
Document Searches
Forms
Help
I::Ir~YJol,!~....O"Ll"i~j
N~~tQ!J_l"l~J
~~Jl,!xrLIQl"l~j
Entity Name Search
I Submit I
No Events
No Name History
Detail by Entity Name
Florida Profit Corporation
DESIGN BUILD ENGINEERS & CONTRACTORS, CORP.
Filing Information
Document Number P01 0001 04056
FEI/EIN Number 593749359
Date Filed 10/25/2001
State FL
Status ACTIVE
Principal Address
801 N MAGNOLIA AVE,
SUITE 406
ORLANDO FL 32803
Changed 04/29/2009
Mailing Address
801 N MAGNOLIA AVE,
SUITE 406
ORLANDO FL 32803
Changed 04/29/2009
Registered Agent Name & Address
THOMPSON, MICHAEL
801 N MAGNOLIA AVE,
SUITE 406
ORLANDO FL 32803 US
Address Changed: 04/29/2009
Officer/Director Detail
Name & Address
Title PD
THOMPSON, MICHAEL
801 N MAGNOLIA AVE, SUITE 406
ORLANDO FL 32803
Annual Reports
Report Year Filed Date
2008 07/08/2008
2009 04/29/2009
2010 01/07/2010
http://sunbiz.org/scripts/cordet.exe?action=DETFIL&inCL doc _ number=PO 1 0001 04056&inq... 3/8/2010
www..sunbiz.org - Department of State
Document Images
Q1}QZl20JJI~-~JjNh! l,JALB~POJn [
Q4(2Q/200Q~- JjNNl,JAl.REPORI [
OZIOS(:ZOOS --JjNNl,JJjl.REPORT [
Q214J(2QQS~~Qff(pir Resign<:iJiQH L
04!24/20Q7~~ ANN l,JAL BEPORT [
04!QQ!2Q06 -- ANN_VAL RII'QRT [
Q4129/20Qp--ANNl,JJjl.REPORT [
07!JQ!2004 -::: ANNVJjl. REPORT [
11146/200~~~ANNVJjLBEPQRT [
lQI07/2Q03-~JjNNVJjL REPORT [
OJIQ9l2QQ~~~ AN NVAl._REEQRT [
10!2S14002 -~ ANNVAl. REPQRT [
10/25/2001 -- Domestic Profit [
View image in PDF format
View imag.e in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PPF format
View image in PDF format
. View image in PDF format
View image in PDF format
View image in PDF format
View image .in PDF format
]
J
]
J
]
J
]
]
J
]
]
]
]
Note: This is not official record. See documents if question or conflict.
No Events
No Name History
Next on List Ret!.!rI1_Tol",i$t
Previous on List
I Home I Contact us I Document Searches I ['-Filing Services I Forms I Help i
Copyngl1t and Pnvacy Policies
Copyright (0) 2007 State of Florida, Department of State.
Page 2 of2
Entity Name Search
I Submit ]
http://sunbiz.org/scripts/cordet.exe?action=DETFIL&in<L doc _ number=PO 1 000 1 04056&inq... 3/8/2010
Www.sunbiz.org - Department of State
Page 1 of2
Home
Contact Us
E-Filing Services
Document Searches
Forms
Help
Previous on List
Next on List
Return To List
IEntity Name Search
No Events
No Name History
Detail by Entity Name
Florida Profit Corporation
DESIGN BUILD ENGINEERS & CONTRACTORS, CORP.
Filing Information
Document Number P01 0001 04056
FEI/EIN Number 593749359
Date Filed 10/25/2001
State FL
Status ACTIVE
Principal Address
801 N MAGNOLIA AVE,
SUITE 406
ORLANDO FL 32803
Changed 04/29/2009
Mailing Address
801 N MAGNOLIA AVE,
SU ITE 406
ORLANDO FL 32803
Changed 04/29/2009
Registered Agent Name & Address
THOMPSON, MICHAEL
801 N MAGNOLIA AVE,
SUITE 406
ORLANDO FL 32803 US
Address Changed: 04/29/2009
Officer/Director Detail
~LoP
. l v-r cuzeir n j)
J;17.
Name & Address
Title PD
THOMPSON, MICHAEL
801 N MAGNOLIA AVE, SUITE 406
ORLANDO FL 32803
Annual Reports
Report Year Filed Date
2007 04/24/2007
2008 07/08/2008
2009 04/29/2009
http://www.sunbiz.org/scripts/cordet.exe?action=DETFIL&in~ doc _ number=PO 1 0001040... 7/17/2009
"www.sunbiz.org - Department of State
Document Images
Q4/2QI2QQQ =-ANNlJAI". Rf;PORT
07/Q&/2QQ&=-ANNlJAL Rf;PQRT
Q2/21j2QQ&=-Qff/PiLResign~tiQn
04/24/2007 -- ANNUAL REPORT
04/QQf20Qp - ANN1JBL R_EPO_RT
Q.4/2W20Q~-=-ANN!JAL-REPO_RT
07[1012004 -- ANNUAl". REPORT
jJ12p/2QQ:.3=_ANNUAL REPORT
10107/2003 - ANNUAL REPORT
01/0Q/2003 - ANNUAL REPORT
10/28/2002 -- ANNUAL REPORT
10/25/2001 -- Domestk.Profit
Note: This is not official record. See documents if question or conflict.
Previous on List
Next on List
No Name History
Return I.QJ"l$t
No Events
I Home I Contact us I Document Searches I E-Filing Services I Forms I Help I
Copyright and Privacy Policies
Copyright ~ 2007 State of Florida, Department of State.
Page 2 of2
IEntity Name Search
http://www.sunbiz.org/scripts/cordet.exe?action=DETFIL&in~ doc _ number=PO 1 000 1 040... 7/17/2009