#09-5287 (Mitchell & Stark Co., Inc.
eoltr County
~-
- ~. ~
Adminisllative Servioos Division
Purchasing
Oil Well Road Widening - Segments 2 and 4A
COLLIER COUNTY BID NO. 09-5287
COLLIER COUNTY, FLORIDA
Design Professional:
CH2M Hill
(j)
..,,~.
Purmasing fJe;;er1rra1t. 3301 Tamiarni Trail East. NapTes. Florida 34112 . vM'W.coHiergov.nelJpurchasing
TABLE OF CONTENTS
A. PUBLIC NOTICE/LEGAL ADVERTISEMENT (PAGE 1 ONLY)
B. INSTRUCTIONS TO BIDDERS
C. BID, BID SCHEDULE AND OTHER DOCUMENTS
D. AGREEMENT
E. AGREEMENT EXHIBITS
EXHIBIT A: Performance and Payment Bond Forms
EXHIBIT B: Insurance Requirement Form
EXHIBIT C: Release and Affidavit Form
EXHIBIT D: Contractor Application for Payment Form
EXHIBIT E: Change Order Form
EXHIBIT F: Certificate of Substantial Completion Form
EXHIBIT G: Final Payment Checklist
EXHIBIT H: General Terms and Conditions
EXHIBIT I: Supplemental Terms and Conditions
EXHIBIT J: Technical Specifications
EXHIBIT K: Permits
EXHIBIT L: Standard Details (if applicable)
EXHIBIT M: Plans and Specifications prepared by CH2M Hill
and identified as follows: Oil Well Road Widening - Segments 2
and 4A, as shown on Plan Sheets for Segment 2 (377 pages) and
Segment 4A (193 pages).
EXHIBIT N: Contractor's List of Key Personnel
eo~ County
~ .~
AdrrinistJative Services Division
Purchasing
PUBLIC NOTICE
INVITATION TO BID
Oil Well Road Widening - Segments 2 and 4A
COUNTY BID NO. 09-5287
Separate sealed bids for the construction of Oil Well Road Widening - Segments 2
and 4A, addressed to Mr. Steve Carnell, Purchasing Director, will be received at the
Collier County Government Complex, 3301 Tamiami Trail East, Purchasing Building,
Purchasing Department, Naples, Florida 34112, until 2:30 P.M. LOCAL TIME, on the
9th day of November 2009, at which time all bids will be publicly opened and read
aloud. Any bids received after the time and date specified will not be accepted and
shall be returned unopened to the Bidder.
A non-mandatory pre-bid conference shall be held at the Purchasing Department,
Conference Room A, Purchasing Building "G" at 2:00 p.m. LOCAL TIME on the 26th
day of October 2009, at which time all prospective Bidders may have questions
answered regarding the Bidding Documents for this Project.
Sealed envelopes containing bids shall be marked or endorsed "Bid for Collier County
Government, Collier County, Oil Well Road Widening - Segments 2 and 4A, Bid No.
09-5287 and Bid Date of November 9, 2009. No bid shall be considered unless it is
made on an unaltered Bid form which is included in the Bidding Documents. The Bid
Schedule (GC-P-1 through GC-P-15) shall be removed from the Bidding Documents
prior to submittal.
One contract will be awarded for all Work. Bidding Documents may be examined on the
Collier County Purchasing Department E-Procurement website: www.collierqov.neUbid.
Copies of the Bidding Documents may be obtained only from the denoted website.
Bidding Documents obtained from sources other than the Collier County Purchasing
Department website may not be accurate or current.
Each bid shall be accompanied by a certified or cashiers check or a Bid Bond in an
amount not less than five percent (5%) of the total Bid to be retained as liquidated
damages in the event the Successful Bidder fails to execute the Agreement and file the
required bonds and insurance within fifteen (15) calendar days after the receipt of the
Notice of Award. The Successful Bidder acknowledges and agrees that it shall execute
the Agreement in the form attached hereto and incorporated herein.
GC-PN-1
(Revised July 2009)
The Successful Bidder shall be required to furnish the necessary Payment and
Performance Bonds, as prescribed in the General Conditions of the Contract
Documents. All Bid Bonds, Payment and Performance Bonds, Insurance Contracts and
Certificates of Insurance shall be either executed by or countersigned by a licensed
resident agent of the surety or insurance company having its place of business in the
State of Florida. Further, the said surety or insurance company shall be duly licensed
and qualified to do business in the State of Florida. Attorneys-in-fact that sign Bid
Bonds or Payment and Performance Bonds must file with each bond a certified and
effective dated copy of their Power of Attorney.
In order to perform public work, the Successful Bidder shall, as applicable, hold or
obtain such contractor's and business licenses, certifications and registrations as
required by State statutes and County ordinances.
Before a contract will be awarded for the Work contemplated herein, the Owner shall
conduct such investigations as it deems necessary to determine the performance record
and ability of the apparent low Bidder to perform the size and type of work specified in
the Bidding Documents. Upon request, the Bidder shall submit such information as
deemed necessary by the Owner to evaluate the Bidder's qualifications.
The Successful Bidder shall be required to finally complete all Work for Segment 2 and
4A within seven hundred and fifty (750) and seven hundred and sixty five (765)
calendar days respectively from and after the Commencement Date specified in the
Notice to Proceed.
The Owner reserves the right to reject all Bids or any Bid not conforming to the intent
and purpose of the Bidding Documents, and to postpone the award of the contract for a
period of time which, however, shall not extend beyond one hundred twenty (120) days
from the bid opening date without the consent of the Successful Bidder.
Dated this 25th day of September 2009.
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
BY: /s/ Stephen Y. Carnell, C.P.M.
Purchasing and General Services Director
GC-PN-2
(Revised July 2009)
PART B - INSTRUCTIONS TO BIDDERS
Section 1.
Definitions
1.1 The term "Owner" used herein refers to the Board of County Commissioners, or
its duly authorized representative.
1.2 The term "Project Manager" used herein refers to the Owner's duly authorized
representative and shall mean the Division Administrator or Department Director, as
applicable, acting directly or through duly authorized representatives.
1.3 The term "Design Professional" refers to the licensed professional engineer or
architect who is in privity with the Owner for the purpose of designing and/or monitoring
the construction of the project. At the Owner's discretion, any or all duties of the Design
Professional referenced in the Contract Documents may be assumed at any time by the
Project Manager on behalf of the Owner. Conversely, at the Owner's discretion the
Project Manager may formally assign any of his/her duties specified in the Contract
Documents to the Design Professional.
1.4 The term "Bidder" used herein means one who submits a bid directly to the
Owner in response to this solicitation.
1.5 The term "Successful Bidder" means the lowest qualified, responsible and
responsive Bidder who is awarded the contract by the Board of County Commissioners,
on the basis of the Owner's evaluation.
1.6 The term "Bidding Documents" includes the Legal Advertisement, these
Instructions to Bidders, the Bid Schedule and the Contract Documents as defined in the
Agreement.
1.7 The term "Bid" shall mean a completed Bid Schedule, bound in the Bidding
Documents, properly signed, providing the Owner a proposed cost for providing the
services required in the Bidding Documents.
Section 2.
Preparation of Bids
2.1 The Bids must be submitted on the standard form herein furnished by the Owner
(pages GC-P-1 to GC-P-15 as bound in these Bidding Documents). By submitting a Bid,
Bidder acknowledges and agrees that it shall execute the Agreement in the form
attached hereto and incorporated herein. The Bidder shall complete the Sid in ink or by
typewriter and shall sign the Sid correctly. Sid Schedules submitted on disk/CD shall be
accompanied by a hard copy of the completed Bid Schedule which shall be signed and
dated by the Sidder. The Sid may be rejected if it contains any omission, alteration of
form, conditional bid or irregularities of any kind. Bids must be submitted in sealed
envelopes, marked with the Sid Number, Project Name and Bid opening Date and Time,
and shall be addressed to the Collier County Purchasing Department, Purchasing
Building, Collier County Government Complex, 3301 Tamiami Trail, East, Naples,
Florida 34112. If forwarded by mail, the sealed envelope containing the Bid must be
GC-IB-1
enclosed in another sealed envelope addressed as above. Bids received at the
location specified herein after the time specified for bid opening will be returned to the
bidder unopened and shall not be considered.
Section 3.
Bid Deposit Reauirements
3.1 No Bid shall be considered or accepted unless at the time of Bid filing the same
shall be accompanied by a cashiers check, a cash bond posted with the County Clerk, a
certified check payable to Owner on some bank or trust company located in the State
of Florida insured by the Federal Deposit Insurance Corporation, or Bid Bond, in an
amount not less than 5% of the bidder's maximum possible award (base bid plus all
add alternates) (collectively referred to herein as the "Bid Deposit"). The Bid Deposit
shall be retained by Owner as liquidated damages if the Successful Bidder fails to
execute and deliver to Owner the unaltered Agreement, or fails to deliver the required
Performance and Payment Bonds or Certificates of Insurance, all within ten (10)
calendar days after receipt of the Notice of Award. Bid Bonds shall be executed by a
corporate surety licensed under the laws of the State of Florida to execute such bonds,
with conditions that the surety will, upon demand, forthwith make payment to Owner
upon said bond. Bid Deposits of the three (3) lowest Bidders shall be held until the
Agreement has been executed by the Successful Bidder and same has been delivered
to Owner together with the required bonds and insurance, after which all three (3) Bid
Deposits shall be returned to the respective Bidders. All other Bid Deposits shall be
released within ten (10) working days of the Bid Opening. No Bid including alternates,
shall be withdrawn within one hundred and twenty (120) days after the public opening
thereof. If a Bid is not accepted within said time period it shall be deemed rejected and
the Bid Deposit shall be returned to Bidder. In the event that the Owner awards the
contract prior to the expiration of the 120 day period without selecting any or all
alternates, the Owner shall retain the right to subsequently award to the Successful
Bidder said alternates at a later time but no later than 120 days from opening, unless
otherwise agreed by the Purchasing Director and the Successful Bidder.
3.2 The Successful Bidder shall execute five (5) copies of the Agreement in the form
attached and deliver same to Owner within the time period noted above. The Owner
shall execute all copies and return one fully executed copy of the Agreement to
Successful Bidder within thirty (30) working days after receipt of the executed
Agreement from Successful Bidder unless any governmental agency having funding
control over the Project requires additional time, in which event the Owner shall have
such additional time to execute the Agreement as may be reasonably necessary.
Section 4.
Riaht to Reiect Bids
4.1 The Owner reserves the right to reject any and all Bids or to waive informalities
and negotiate with the apparent lowest, qualified Bidder to such extent as may be
necessary for budgetary reasons.
Section 5. SiQnina of Bids
5.1 Bids submitted by a corporation must be executed in the corporate name by the
GC-18-2
president, a vice president, or duly authorized representative. The corporate address
and state of incorporation must be shown below the signature.
5.2 Bids by a partnership must be executed in the partnership name and signed by a
general partner whose title must appear under the signature and the official address of
the partnership must be shown below said signature.
5.3 If Bidder is an individual, his or her signature shall be inscribed.
5.4 If signature is by an agent or other than an officer of corporation or general
partner of partnership, a properly notarized power of attorney must be submitted with
the Bid.
5.5 All Bids shall have names typed or printed below all signatures.
5.6 All Bids shall state the Bidder's contractor license number.
5.7 Failure to follow the provisions of this section shall be grounds for rejecting the
Bid as irregular or unauthorized.
Section 6.
Withdrawal of Bids
Any Bid may be withdrawn at any time prior to the hour fixed in the Legal Advertisement
for the opening of Bids, provided that the withdrawal is requested in writing, properly
executed by the Bidder and received by Owner prior to Bid Opening. The withdrawal of
a Bid will not prejudice the right of a Bidder to file a new Bid prior to the time specified
for Bid opening.
Section 7.
Late Bids
No Bid shall be accepted that fails to be submitted prior to the time specified in the
Legal Advertisement.
Section 8.
Interpretation of Contract Documents
8.1 No interpretation of the meaning of the plans, specifications or other Bidding
Documents shall be made to a Bidder orally. Any such oral or other interpretations or
clarifications shall be without legal effect. All requests for interpretations or clarifications
shall be in writing, addressed to the Purchasing Department, to be given consideration.
All such requests for interpretations or clarification must be received at least ten (10)
calendar days prior to the Bid opening date. Any and all such interpretations and
supplemental instructions shall be in the form of written addendum which, if issued,
shall be sent by mail or fax to all known Bidders at their respective addresses furnished
for such purposes no later than three (3) working days prior to the date fixed for the
opening of Bids. Such written addenda shall be binding on Bidder and shall become a
part of the Bidding Documents.
GC-IB-3
8.2 It shall be the responsibility of each Bidder to ascertain, prior to submitting its Bid,
that it has received all addenda issued and it shall acknowledge same in its Bid.
8.3 As noted in the Legal Advertisement, attendance by all bidders at the Pre-Bid
Conference is non-mandatory.
Section 9.
Examination of Site and Contract Documents
9.1 By executing and submitting its Bid, each Bidder certifies that it has:
a. Examined all Bidding Documents thoroughly;
b. Visited the site to become familiar with local conditions that may in any manner
affect performance of the Work;
c. Become familiar with all federal, state and local laws, ordinances, rules, and
regulations affecting performance of the Work; and
d. Correlated all of its observations with the requirements of Bidding documents.
No plea of ignorance of conditions or difficulties that may exist or conditions or
difficulties that may be encountered in the execution of the Work pursuant to these
Bidding Documents as a result of failure to make the necessary examinations and
investigations shall be accepted as an excuse for any failure or omission on the part of
the Successful Bidder, nor shall they be accepted as a basis for any claims whatsoever
for extra compensation or for an extension of time.
9.2 The Owner will make copies of surveys and reports performed in conjunction with
this Project available to any Bidder requesting them at cost; provided, however, the
Owner does not warrant or represent to any Bidder either the completeness or accuracy
of any such surveys and reports. Before submitting its Bid, each Bidder shall, at its own
expense, make such additional surveys and investigations as may be necessary to
determine its Bid price for the performance of the Work within the terms of the Bidding
Documents. This provision shall be subject to Section 2.3 of the General Conditions to
the Agreement.
Section 10.
Material Reauirements
It is the intention of these Bidding Documents to identify standard materials. When
space is provided on the Bid Schedule, Bidders shall specify the materials which they
propose to use in the Project. The Owner may declare any Bid non-responsive or
irregular if such materials are not specifically named by Bidder.
Section 11. Bid Quantities
11.1 Quantities given in the Bid Schedule, while estimated from the best information
available, are approximate only. Payment for unit price items shall be based on the
actual number of units installed for the Work. Bids shall be compared on the basis of
number of units stated in the Bid Schedule as set forth in the Bidding Documents. Said
GC-18-4
unit prices shall be multiplied by the bid quantities for the total Bid price. Any Bid not
conforming to this requirement may be rejected. Special attention to all Bidders is
called to this provision, because if conditions make it necessary or prudent to revise the
unit quantities, the unit prices will be fixed for such increased or decreased quantities.
Compensation for such additive or subtractive changes in the quantities shall be limited
to the unit prices in the Bid. Subsequent to the issuance of a notice to proceed, the
Project Manager and the Successful Bidder shall have the discretion to re-negotiate any
unit price(s) where the actual quantity varies by more than 25% from the estimate at the
time of bid.
Section 12.
Award of Contract
12.1 Any prospective bidder who desires to protest any aspect(s) or provision(s) of the
bid invitation (including the form of the bid documents or bid procedures) shall file their
protest with the Purchasing Director prior to the time of the bid opening strictly in
accordance with Owner's then current Purchasing Policy.
12.2 The Collier County Board of County Commissioners has adopted a Local
Preference "Right to Match" policy to enhance the opportunities of local businesses to
receive awards of Collier County contracts.
A "local business" is defined as a business that has a valid occupational license issued
by either Collier or Lee County for a minimum of one (1) year prior to a Collier County
bid or proposal submission that authorizes the business to provide the commodities or
services to be purchased, and a physical business address located within the limits of
Collier or Lee Counties from which the vendor operates or performs business. Post
Office Boxes are not verifiable and shall not be used for the purpose of establishing said
physical address. In addition to the foregoing, a vendor shall not be considered a "local
business" unless it contributes to the economic development and well-being of either
Collier or Lee County in a verifiable and measurable way. This may include, but not be
limited to, the retention and expansion of employment opportunities, the support and
increase to either Collier or Lee County's tax base, and residency of employees and
principals of the business within Collier or Lee County. Vendors shall affirm in writing
their compliance with the foregoing at the time of submitting their bid or proposal to be
eligible for consideration as a "local business" under this section.
When a qualified and responsive, non-local business submits the lowest price bid, and
the bid submitted by one or more qualified and responsive local businesses is within ten
percent (10%) of the price submitted by the non-local business, then the local business
with the apparent lowest bid offer (i.e. the lowest local bidder) shall have the opportunity
to submit, an offer to match the price(s) offered by the overall lowest, qualified and
responsive bidder. In such instances, staff shall first verify if the lowest non-local bidder
and the lowest local bidder are in fact qualified and responsive bidders. Next, the
Purchasing Department shall determine if the lowest local bidder meets the
requirements of Section 287.087 F.S.
GC-18-5
If the lowest local bidder meets the requirements of 287.087, F.S., the Purchasing
Department shall invite the lowest local bidder to submit a matching offer to the
Purchasing Department which shall be submitted within five (5) business days
thereafter. If the lowest local bidder submits an offer that fully matches the lowest bid
from the lowest non-local bidder tendered previously, then award shall be made to the
local bidder. If the lowest local bidder declines or is unable to match the lowest non
local bid price(s), then award will be made to the lowest overall qualified and responsive
bidder. If the lowest local bidder does not meet the requirement of Section 287.087 F.S.
and the lowest non-local bidder does, award will be made to the bidder that meets the
requirements of the reference state law.
Bidder must complete and submit with their bid response the Affidavit for Claiming
Status as a Loca/ Business which is included as part of this solicitation. Failure on the
part of a Bidder to submit this Affidavit with their bid response will preclude said
Bidder from being considered for local preference on this solicitation.
A Bidder who misrepresents the Local Preference status of its firm in a bid submitted to
the County will lose the privilege to claim Local Preference status for a period of up to
one year.
The County may, as it deems necessary, conduct discussions with responsible bidders
determined to be in contention for being selected for award for the purpose of
clarification to assure full understanding of, and responsiveness to solicitation
requirements.
12.3 Award recommendations will be posted outside the offices of the Purchasing
Department generally on Wednesdays and Thursdays prior to the presentation to the
Board of County Commissioners. Award of Contract will be made by the Board of
County Commissioners in public session. Any actual or prospective bidder who desires
to formally protest the recommended contract award must file a notice of intent to
protest with the Purchasing Director within two (2) calendar days (excluding weekends
and holidays) of the date that the recommended award is posted. Upon filing of said
notice, the protesting party will have five (5) days to file a formal protest, said protest to
strictly comply with Owner's then current Purchasing Policy. A copy of the Purchasing
Policy is available at the offices of the Purchasing Director.
12.4 For Bidders who may wish to receive copies of Bids after the Bid opening, The
Owner reserves the right to recover all costs associated with the printing and distribution
of such copies.
Section 13.
Sales Tax
13.1 The Successful Bidder acknowledges and agrees that Owner may utilize a sales
tax savings program and the Successful Bidder agrees to fully comply, at no additional
cost to Owner, with such sales tax savings program implemented by the Owner as set
forth in the Agreement and in accordance with Owner's policies and procedures.
GC-IB-6
Section 14.
Exclusion of County Permits in Bid Prices
14.1 To ensure compliance with Section 218.80, F.S., otherwise known as "The Public
Bid Disclosure Act", Collier County will pay for all Collier County permits and fees
applicable to the Project, including license fees, permit fees, impact fees or inspection
fees applicable to this Work through an internal budget transfer(s). Hence, bidders shall
not include these permiUfee amounts in their bid offer. However, the Successful Bidder
shall retain the responsibility to initiate and complete all necessary and appropriate
actions to obtain the required permits other than payment for the items identified in this
section.
14.2 The Successful Bidder shall be responsible for procuring and paying for all
necessary permits not issued by Collier County pursuant to the prosecution of the work.
Section 15.
Use of Subcontractors
15.1 To ensure the Work contemplated by the Contract Documents is performed in a
professional and timely manner, all Subcontractors performing any portion of the work
on this Project shall be "qualified" as defined in Collier County Ordinance 87-25,
meaning a person or entity that has the capability in all respects to perform fully the
Agreement requirements and has the integrity and reliability to assure good faith
performance. A Subcontractor's disqualification from bidding by the Owner, or other
public contracting entity within the past twelve months shall be considered by the Owner
when determining whether the Subcontractors are "qualified."
15.2 The Owner may consider the past performance and capability of a Subcontractor
when evaluating the ability, capacity and skill of the Bidder and its ability to perform the
Agreement within the time required. Owner reserves the right to disqualify a Bidder who
includes Subcontractors in its bid offer which are not "qualified" or who do not meet the
legal requirements applicable to and necessitated by this Agreement.
15.3 The Owner may reject all bids proposing the use of any subcontractors who have
been disqualified from submitting bids to the Owner, disqualified or de-certified for
bidding purposes by any public contracting entity, or who has exhibited an inability to
perform through any other means.
15.4 Notwithstanding anything in the Contract Documents to the contrary, the Bidders
shall identify the subcontractor(s) it intends to use for the categories of work as set forth
in the List of Subcontracts attached hereto, said list to be submitted with its bid. Bidders
acknowledge and agree that the subcontractors identified on the list is not a complete
list of the subcontractors to be used on the Project, but rather only the major
subcontractors for each category of Work as established by Owner. Bidders further
acknowledge that once there is an Award of Contract, the Successful Bidder shall
identify, subject to Owner's review and approval, all the subcontractors it intends to use
on the Project. Once approved by Owner, no subcontractor shall be removed or
replaced without Owner's prior written approval.
GC-IB-7
Section 16.
Prohibition of Gifts
No organization or individual shall offer or give, either directly or indirectly, any favor,
gift, loan, fee, service or other item of value to any County employee, as set forth in
Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05,
and County Administrative Procedure 5311. Violation of this provision may result in one
or more of the following consequences: a. Prohibition by the individual, firm, and/or any
employee of the firm from contact with County staff for a specified period of time; b.
Prohibition by the individual and/or firm from doing business with the County for a
specified period of time, including but not limited to: submitting bids, RFP, and/or
quotes; and, c. immediate termination of any contract held by the individual and/or firm
for cause.
Section 17.
Public Entity Crimes
By its submitting a Bid, Bidder acknowledges and agrees to and represents it is
in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read
as follows:
"A person or affiliate who has been placed on the convicted
vendor list following a conviction for a public entity crime
may not submit a bid, proposal, or reply on a contract to
provide any goods or services to a public entity; may not
submit a bid, proposal, or reply on a contract with a public
entity for the construction or repair of a public building or
public work; may not submit bids, proposals, or replies on
leases of real property to a public entity'; may not be
awarded or perform work as a contractor, supplier,
subcontractor, or consultant under a contract with any public
entity; and may not transact business with any public entity
in excess of the threshold amount provided in s. 287.017 for
CATEGORY TWO for a period of 36 months from the date of
being placed on the convicted vendor list."
GC-18-8
c& County
---~ ... ...,9
Adminisllative Services Division
Purchasing
Email: BrendaBrilhart@collierQov.net
Telephone: (239) 252-8446
FAX: (239) 252-6697
ADDENDUM
Memorandum
Date~ October 14, 2009
FroV Brenda Brilhart, Purchasing Agent
To: Interested Bidders
Subject:
Addendum #1 - ITB # 09-5287 - Oil Well Road Widening - Segments 2 and 4A
The following clarifications are issued as Addendum #1 identifying the fOllowing change for the
referenced bid:
CHANGE: A non-mandatory pre-bid conference shall be held at the Purchasing Department,
Confer-ence Room ^, Purchasing Building "G" Risk Manaqement Buildinq "50" at 2:00 p.m.
LOCAL TIME on the 26th day of October 2009, at which time all prospective Bidders may have
questions answered regarding the Bidding Documents for this Project.
If parking is not available in the lot in front of the Risk Management Building, proceed to parking
garage.
If you require additional information please post a question on the eBid site or contact me (contact
information above).
c: Gary Putaansuu, Project Manager
Ene: Campus Map
p;:;~~
Appnl*
4
'-,
"
"
'.'"
"',
"
'-
",
" ...// "~ j'''\ ,/"" "'\.,.-:f;i
,~" ,. f/ '-~\
A>~ F'\ c'/<" Hum.~~,~
<{~>".,,:;~~~~~~,,),_,(.~ .' R~B~/~'/" "',
;:., .~~'" -')1'<../' '-" /
'<:;;</,-"",~)jf' ~--> ",
.~~ r' < '~.(~ >>:?!~''i' ~
I '~bj'
(:Y"
" ?,)"
Court Plaza
SI Matthews House
Elllst Naples
Methodlsl Churth
Q
<
~
i;;
~
:;;:
:.1
Tax CoUector \
1 3-C-1 l
'Elections
i 2-c
//"',-:"
Ad"';'inistratlOn
\, 7-F ",/ /'
:::'-;/
"
"
Po
'"
'1",(
<"J'
,
"
~'"
'-."."
(,oJ'
.~
00,
<"~
/
Finance
15
, , ' , 'lLLl j/'"
-'~'Hellth and /'
, Commanlty~~-!-
---ServIces tee
9-H
Collier Juvenile
Detention Center
GUl' """ I JjlJJ'
'-rrr;ff;-~~T"~-rf-r' ;
I, ,i ::f'o,II,ILJ'
('!\ii,j:III:r.llf, ...,
~..u,....Li.N._1
\jlll:I;!liiii~~I!/' ---::<
lUJUUllJ'mf"1 ~
'H'1mnmmV c,
,
L."
; ._..~~~, ,~,Ll. ;"'~"'_.
',__./F--',
-i
Sherll1'.
Administration
aDd Jail
"
'"
! 10-J
Parking
Garage
/
//
r-J
-", (.,\
'-,
Facilities '-',)
Manacementt",.
_ 14-W L
, ----;
,Clilller Purth..lng
"lee. PI~nl '8-6 "
, ,
( ~".,
't
'\
\\
;;:-.;.\
\\
I
t../////,,/"-\, {" _ ' (, /'~, <~~>/i / '"
<" " <., /(y- ~J0, / ~iise,.~
/ ~/"j'C '''\, ".5<((:, /";,.{<: /' "'<:/, "\ < 13~M
. / \ '\~~~. /';-,'<// \ ~</;) ,/
.'/~'/ /:'('~_ ::?\ '! \~;~" '>;.if,
.' ,""" ..;: '! '\'."-
// C /./ I '{,"
"-"'< ~j J
.~
~y Parking
'PY' Garage
/
"\
, '
,/
"
,/'
//
/
/
/
N
"
,
,
./'
~~
~(i<
E
w
"'0
~
..,~
5
SCAlf: 1'~250'
;':""TraffM: ",~
Ughl
""
""
""
""
,
'"
Colt.- County
~. -
Adminisllative Services Division
Purchasing
Email: BrendaBrilhart@collierQov.net
Telephone: (239) 252-8446
FAX: (239) 252-6697
ADDENDUM
Memorandum
Date:
November 3, 2009
From:
Brenda Brilhart, Purchasing Agent
To:
I nterested Bidders
Subject:
Addendum #2 - ITB # 09-5287 - Oil Well Road Widening - Segments 2 and 4A
The following clarifications are issued as Addendum #2 identifying the following change for the
referenced bid:
. The due date for this bid has been extended until November 18, 2009.
If you require additional information please post a question on the eBid site or contact me (contact
information above).
c: Gary Putaansuu, Project Manager
Co. County
~. ~
AdministJative Servioos Division
Purchasing
Email: BrendaBrilhart@collierQov.net
Telephone: (239) 252-8446
FAX: (239) 252-6697
ADDENDUM
Memorandum
Date:
November 10, 2009
From:
Brenda Brilhart, Purchasing Agent
To:
Interested Bidders
Subject:
Addendum #3 - ITB # 09-5287 - Oil Well Road Widening - Segments 2 and 4A
The following clarifications are issued as Addendum #3 identifying the following change for the
referenced bid:
. Bidders on any service related project, including construction, must be qualified and directly
responsible for 30% or more of the solicitation amount for said work.
. Revised Bid Schedule and summary of changes attached.
. Revised Plan Sheets Segment 2a and 4.
. On Segment 2, delete line item no. 109-71-5 Field Office - Owner will provide field office.
. Follow Roadway Specifications - 334 Superpave.
If you require additional information please post a question on the eBid site or contact me (contact
information above).
c: Gary Putaansuu, Project Manager
Enc: Bid Schedule
Plan Sheets
Summary Sheet
Pre Bid Meeting Attendees List
(")
'l<
2
::J 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0
z 0 0 0 0 0 0 0 0 0 0
w 0 0 0 0 0 0 0 ... ... 0
0 0 0 0 0 0 0 0 0
0 ,..: 0 III III 0 0 ,..: .....
<( it) <D ... M -.t 0 0 0
it) M ... ... ... N N N
... ... ... N N
... ... ...
VI
(I)
-0
..!!!
-oCl
r-- ('II ~
CIO 0 (I)
l;:la::Jj
,
g:(I).s
CS:3l
IIlO.ll1
o
E
E
c:(
"It
"It
o
o
<D
d
z
I-
o
W
..,
o
a::
a.
~
z
~
o
o
a::
w
:J
...I
o
o
~
o In
ClE
ell Q)
';G:::::
U >-
... '"
ca.
::::1>-
0<(
Es:
~O
"'<(
"'0
~o:::
- In
~E
o Q)
Cl""
ell >-
... '"
"'a.
Uoo
CW
::::10:::
0::J
EI--
<(U
1ii::J
...0:::
01--
1--00
(J)
E
~
>-
'"
a.
00
(9
z
52
0:::
<(
2
I--
-z
~W
02
ClW
~;:;:
~a.
...0
Cz
g<(
E(9
<(~
liiZ
-0(9
1--00
~ E
~2
0-
Ol>-
ell '"
....a.
"'z
~O
cl--
g;;j
E-
<(~
-z
.19(9
0-
1--00
>
~
o
Olin
~ E
'" Q)
U""
.... >-
C '"
::::Ia.
0(9
Ez
<(I--
Iii I
-0(')
1---'
:>
~
o
Olin
ell E
-:: .,
.. ~
0-
.... >-
C '"
::::I a.
000
Ew
<(i=
-;:J
O~
I--::J
:>
III
ell
";:
o
Cl
ell
...
'"
U
I--
Z
::J
e
:;;
<(
o
iXi
w
00
<(
III
..J
<(
I--
e
I--
<(Ill
WW
1-1-
<(<(
ZZ
0:::0::
WW
1-1--
..J..J
<(<(
Ul
W
I-
<(
Z
0::
w
I-
..J
<(
Ul
::J
..J
D-
O
III
W
Ul
<(
III
..J
<(
I--
e
I--
M
"
"
::>
Cl
z
W
Cl
Cl
"
w
"
'tl
..
C.
~
"
>
W
o
-
~N~
~ 1: ~
cACD-
oE~
c Ol 0
- " E
<Xl(/),[
'tl
..
o
cr:
~
6
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '"
s
0
f-
"
"
'C
a.
-
'"
:::J
~ ~ ~ ~ ~ ~ <Xl 0 <Xl 0 N ...~ 0 0> 0> <Xl 0>
'" ~ "' 0> 0 '" <Xl '" "'
N_ ~ .,. f"- ~ 0 0> "' '" "'-
> ~ N- O oJ oi oi ~
f- N ~ '" N
a ~ N
- <( '-'
'" (f) (f) (f) (f) 0 (f) "- "- "- <( ~ > > > > > >
:::J --' --' --' --' (Jj --' --' --' --' 0 (f) '-' '-' '-' '-' (f) (f)
--' --'
~
0 f-
'" :::J
Q. a
'C >
" :5
..
"
c 0
E z (f) UJ
<( f-
~ Z --'
(9 :::J
(f) Z UJ C
Z >= ::; UJ g
:5 :J
UJ Z J:
"- > a '-' "-
cr: (f) cr:
~ ::; :::J
:J f- W cr: - a
(f) > '-' 0: -
:J UJ UJ '-' UJ UJ (9 cr:
~ (l] z > ~ u: cr: 0: "- (9
a cr: a "- ~ cr: ~ z cr: --' UJ
(f) a; :5 --' UJ
~ >= :J cr: ;? <( 0 z (l] (f)
c '-' (f) "- > (l] (l] <(
<( f- f- W :J :::J (f) Z UJ ~
Z :J "- Z 0 i'= '-' cr: (9 (l] <( "-
0 ~ cr: 0 ~ "- z (9 UJ :::J I i'=
cr: f- a a; 0 UJ cr: (f) '-' --'
. (f) z
z z UJ cr: a; "- 0 , , z <(
- z ~ z 0 '-' :J UJ Z f- a z
a a !;: ;;: cr: ':J z z z z
~ '-' ::; Z f- :J '-' <( a a a UJ ~ a
>= <( u: (9 >=
0 ~ w > w (9 f- (f) >= >= >= ::;
UJ cr: z z "- z '" "-
C> 0 0 0 UJ !;: 0 0 a 0: ~ ~ ~ Z :J a
w :J '> '> w '> f- UJ UJ
~ a; (f) z '" '" 0 <( ~ a; UJ
a a UJ a a ~ ~ --' UJ '-' '-' '-' ~ (f)
u a cr: cr: cr: cr: ;;: --' UJ --' x G'i x ::; <(
::; "- "- "- "- ::; "- (f) (f) u: '-' UJ UJ UJ (f) (l]
ci N '"? ~ N ~ '" ~ .,.
z ~ , , 0 ~ J, r::. ;. ~ .,. "' '" .,. 0
, ~ N ~ 0 0 0 0 0 f"-
a , , , 0 -+ -+
E ~ 0 0 -+ d, 0 N N N N '" J,
0 0 0 0
~ ~ ~ ~ ~ ~ 0 0 ~ ~ ~ ~ ~ ~ <Xl
~ ~ ~ ~ ~ ~ N
~
"6
M
..
"
::>
o
z
w
o
o
'"
u;
"
'0
..
C,
~
"
>
W
o
-
tiN~
~~~
tAC1)-
oE~
c en 0
- " E
m"',[
'0
..
o
0::
~
6
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
.. .. .. .. .. .. <F> .. <F> <F> <F> <F> .. .. <F> <F> <F> ..
]
0
I-
"
u
."
"-
-
'"
=>
V <0 '" '" N .... N '" N .... V '" '" N ~ V '" "'
'" '" '" '" '" v '" '" v '" v '" ~
<0 0 0 N 0 0_ v ~
~ N- '" ....- N '" 0
'" '" '"
a ~ ~ ~ N
-
'" >- >- >- >- >- >- >- >- >- <( L'5 L'5 L'5 <( L'5 <( L'5 L'5
=> (fJ (fJ (fJ (fJ (fJ (fJ (fJ 0 0 w W w
N
N
J,
....
CJ
e:. =>
'" '" "' -'
~ c:- o ~
c N N ~ >-
0 N N iO I-
'" J, J, :>
c. .... .... N
"5 '" CJ CJ ~ Iii
0 c:- e:. e:. 0 CJ
" ~
c 0 0- 0 w 0:: 5'
E (fJ 0 ~
,1! 0 0 0 0:: ~
u: u: u: ::> l- => if) 5' -
"- "- "- z -' C
- Iii Iii Iii 0 w ~ ::> ~ 0
5' ~ 0 " 0
~ ~ c. c. c. z w - "
w z W
"- "- a > CJ 0
::> ::J 0 0 0 f= il: z :'i w w
0 0 z z Z
0:: 0:: 0 0 0 0 z -' "- "-
'" I- ~ W >- ~
CJ CJ 0 0 0 -' 0 5' 5' C.
0 0 0 "- <( '!! 5' 5' 5'
w w W I w ~ ~ ~ ~ ~ - -
(fJ (fJ f= f= 5 I- "- "S ~ :!.- :!.- :!.- :!.- !'o " " 5' 5'
<1i <( -' -'
~ <( <( <( w (fJ w w iO "' 0 0 ~ ~
I I I 0:: <( l- I- "I "I "I 1= 1= :!.- !'o
0 <b. <b.
-' -' "- "- "- z (fJ w w 2- 2- 2- 0 0 "'
<( <( (fJ (/) (/) 0 ::J 0:: 0:: CD Cll iO
z z <( <( <( 0 0 0 0 m m m m m <b. <b.
0 0 w w W w z Z 0:: 0:: 0:: 0:: 0:: I I
f= f= > > > 0 z 0 0 => ::J ::J ::> ::J 0 0 (/) (/)
<( <( <( 5 :'i 0 0 8 8 8 8 8 l- I- w w
"- "- "- "- "- - - e- o -' -'
0 0 -'
0:: 0:: 0:: <( w (/) (/) (/) (/) (/) (/) (/) 0 0
w w w w W I 0 (/) (/) l- I- l- I- l- I- l- I I
(/) (/) "- "- "- "- :'i :'i w w w W W W W Z z
<1i <1i => => ::> (/) (/) -' -' -' -' -' -' -' ~ <(
(/) (/) (/) <( ~ 0 0 z z z z z z z "
ci 0 v '" v 0 ~ "' "' ~ "' ~ N :;; '" N
~ 'i' 'i' 'i' '7 <0 "' <D <0
Z ;:: ;;: , , '7 1" 1" 1" "( "(
E "' .... d, ~ ~ ~ N N
"' -+ -+ -+ r-C '" '" '" "' "' "' "' "' "' "' "' "'
,1! '" '" '" '" '" '" '" 0 0 N N
N N '" '" '" '" v V N N N N N N N V V
V V V V V V V
m
o
N
M
"
"
::>
Cl
z
W
Cl
Cl
<C
..
..
'0
..
C.
~
..
>
W
o
-
tiN~
~~~
d,Gl-
oE'=
C Ol 0
- .. E
mUlg
'0
..
o
0::
<i
:;:
6
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
ci ci ci ci ci ci ci ci ci ci ci ci ci ci 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '"
~
0
I-
..
<>
'l:
"-
-
'c
:::>
'" N <Xl I"- <Xl 0 "' N "' Cl) " '" Cl) Cl) <Xl ~ ~ ~
'" I"- Cl) '" "' '" 0 I"- <Xl N <Xl <Xl "'
<Xl " <Xl ~ "' <Xl "- ~ ~ "'- " "
~ <D .; "' cri <<i N- ~ ~ ~ ~ .; .;
a
- <C
'c <C u.. u.. u.. u.. u.. u.. u.. u.. u.. u.. u.. u.. L'5 L'5 <C L'5
:::> w w -' -' -' -' -' -' -' -' -' -' -' -' w
"
N
0
I-
(L '" '" 0 1D
2- ~ ~ ~ ~
6' 6' 6' 6' 6'
z z z z z
:::> => => => =>
" 0 0 0 0 0
0 '" " 0 1D N '" " 0 N eo. 0:: 0:: 0:: 0::
~ ~ ~ ~ ~ ~ ~ !!2. ~ t:. 52 -' -' -' -'
:::J :::J :::J :::J :::J :::J :::J :::J :::J <C <C <C <C
'l: <C <C <C <C <C <C <C <C <C ~ z z z z
<>
'" "' "' "' "' "' "' "' "' "' 0 0 0 0
.. w w w w w w w w w 0 ~ 'E. >= >= >= >=
C l- I- l- I- l- I- I- ~ ~ w (L (L (L (L
E <C <C ~ ~ ~ <C ~ c 6' 6' Q. Q. Q. Q.
i! ::; ::; ::; ::; ::; 0- w w 52 52 52 52
-' -' -' -' -' -' -' -' -' (f) (f)
<C <C <C <C <C <C <C <C <C :::J <C tS ~ ~ ~ ~
z z z z z z z z z <C 0
0 0 0 0 0 0 0 0 0 "' z z C 0 0 0
>= >= >= >= >= >= >= >= >= w w w (f) (f) (f) (f)
(L (L (L (L (L (L (L D.- (L l- I- I- (f) (f) (f) (f)
Q. Q. Q. Q. Q. Q. Q. Q. Q. <C 0 0 0 0 0 0
::; ~ ~ 0:: 0:: 0:: 0::
> > > > > ::; > ::; ::; -' S!- S!- S!- S!-
-' -' -' -' -' -' <C 0- 0-
=> => => => => => => => => z " " z z z z
0- 0- 0 0 0 0 0 0 0 0 0 0 w w 0 0 0 0
~ ~ 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: >= -' -' >= >= >= >=
:f- ie.- w w w w w w w w w (L => => 0 0 0 0
s s s s s s s s S Q. 0 0 w w w w
O? C? w w w w w w w w w w w (f) (f) (f) (f)
(f) (f) (f) (f) (f) (f) (f) (f) (f) l- I I 0 0 0 0
3 3 0:: 0 0
(/) (f) ::; ::; ::; ::; ::; ::; ::; ::; ::; w ~ ~ z z z z
w W 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: > W W W W
-' -' 0 0 0 0 0 0 0 0 0 -' 0 0 0 c 0 0
0 0 l- I- l- I- l- I- l- I- l- => > > w w w W
I I (f) (f) (f) (f) (f) (f) (f) (f) (f) 0 (L D.- o:: 0:: 0:: 0::
Z Z W W W W W W W W W W W W W W W W
~ ~ (L (L (L (L (L D.- (L (L (L (L (L (L l- I- l- I-
0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: ~ ~ ~ ~
"' Cl) '" <Xl 0 l' N '" "' 0 '" <Xl N "' '" <Xl
0 0; N ~ ~ '? '? 'f 'f 'f 'f ~ ~ N '" '"
Cl) ~ ~
z N N ;:: ;:: ;:: ;:: ;:: ~ ;:: ;:: ;:: -+ "' N N N N
l"-
E ,;, ,;, ~ ~ ~ ~ ~ I"- <0 <Xl <Xl <Xl ro
0 0 0 0 0 0 0 0 0 Cl) Cl) '\' '\' Cl) Cl)
i! N N 0 0 0 0 0
" " '" '" '" '" '" '" '" '" '" 0 0
" " " " " " " " " '" '" '" '" '" '" '"
" " " " " " "
~
15
M
~
"
"
::>
o
z
Ui
o
o
.,
.,
"
."
.!!!
Cl
-
"
>
w
.9
~N~
~~i
chG>-
oEJ:
'" Cl 0
m~~
."
..
o
l>:
;;
s:
o
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
<fl <fl <fl <fl <fl <fl <fl <fl <fl <fl <fl <fl <fl '" '" '" <fl '"
Ii
0
I-
"
"
."
"-
'"
"
::>
~ N ..,. N t- O) <Xl ..,. N N t- O) a; .~ 0 <Xl CO CO
0 CO t- O 0 <Xl 0 N <Xl
<0 CO t-_ 0) <Xl ~ N ~ ~ 0)
~ 6 ~ ",- ri N <0
<0 N
a
- <( <( Lli >- ...!5 Lli <( <(
.~ "- "- "- LL LL LL >- 2 LL LL
::> w w --' --' --' --' --' --' (fj (fj I- --' W W --'
N " l>:
::!- !9- w
io f:
is is ~ ::>
2 2 is (9
::> :::J
0 0 2 ., ~
" ::>
.9 0:: 0:: 0 m is w
--' --' 0:: --'
C. <( <( 0:: :::J W --' -
." 2 2 --' 0 0:: ~ W
" 0 0 <( ::i "-
on 2 W- 0 <( >-
" F F 0 (3 ~ eo t:.
'" "- "- 0
E Q. Q. F :::: "' ~ >- >-
"- --' --' is
~ Z Z Q. -" SZ m m m
~ --' :2' :2' :2' f--
~ ~ z ~ ~ --' ~
~ ~ w w W W
~ W W- i>:' 0:: (fj (fj (fj e:-
o 0 w SZ 0_ (fj (fj (fj
(fj (fj f-- W W w 0:: w <( <( <( I
0 ~ "- "- "- w 0 IO (9
(fj (fj >- >- "' ~ (fj- w w w
0 0 w ~ t- t:. t:. I fil 00:: (9 (9 (9 ill
0:: 0:: 0 0:: ?- 2m ~ ~ ~ I
~ ~ fil ~ 0 0 is 0- <( --' <(tt b
m ~ ~
2 2 2 2 2 W 2 ""0:: ~ ~ 0 0 0 cO
w 0 0 "- W I I I
0 0 0 0 "" ::> 2w ~ ,
9 0 0 t- f-- --' ~ 0 0 0
F F F ~ w ~ f-- ~~ 2 2 2 S
:::J 0:: 0:: 0:: 0
0 0 0 ~ w w m 0:: 0 w -li: 0 0 <( <( <( ;;:
w w w f: f: 0:: 0 2 W t: ':10 (!i :2' 0 0 0
(fj (fj (fj --' :::J f-- 0 9 I W 2 Z Z W
0 0 0 ~ :::J :::J 0 ~ 0 0 mw e:. e:. w w w "-
2 2 Z (9 (9 (fj m(9 >-
0:: --' --' --' --' --'
w w w 0 0 0 w <( Cl: W <( :::J(fj ~ ~ ~ ~ ~ t:.
f-- "- W I- e:.w
0 0 0 z z z w w 0 w Vi (9
w w w <( <( <( Cl: (fj --' 0:: 0:: ,,-0 0 0 0 0 0 Z
0:: Cl: Cl: I m m 0 ::> 0 ~3 0:: 0:: 0:: 0:: 0:: 0
"- W
W W W w 0:: 0:: Z ~ 0 z <( <( <( <( <(
f-- l- f-- > ,,-0 z
"- ::> :::J 0 I 0 <( ::> :::J :::J :::J :::J W
~ ~ ~ a: -2
0 0 0 f-- (fj 0 "- 0::- (9 (9 (9 (9 (9 LL
0 N co 0
ci ..,. ..,. N 0 l' co N ..,. co ~
~ I";- ~ 'f N N ":' '" , '" N N N
Z N N .J- , <7 r- ,}, ,}, ,},
~ N co l";- N 6
<Xl <Xl <Xl , 6 6 ,}, ,}, ,}, <Xl '? '?
E 'i' 'i' en co 6 6 N 0 ,}, ~
N N N co N '" '" "' co co 6
~ 6 .r; N N co
0 0 co co co co co co co co "' "' "' co
"' "' '" co co co
..,. ..,. ..,. co
~
"6
..
M
..
'"
::>
o
z
UJ
o
o
'"
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" 0 0
0 0
....- ci
'" '"
S "'-
0 ;;;
f-
0 0
0 0
0 0
0 0
CI> 0 0
" ....- ci
~ '" '"
- "'-
." ;;;
:>
N 0 0> '" ~ ~ N '" ~ N
" '" .... "
~ " "'- <0
~ ~ <6
0>
a ~
-
'" (L (L (L <( ~ ~ <( >- (f) ~
:> --' --' --' LU LU (f) --'
r:: 6' 6' 6' 6'
0 z
., z z z Z (f)
Q. Z Z Z LU z
"5 LU LU LU Cl. CJ
on Cl. Cl. Cl. 0 en
CI> 0 0 0 0
0 0 0 0 0 f-
E 6" 6" oci oci 0 0 z
~ 6" f- f- ~ ~ N '" LU
f- '!2. '!2. , , :a:
'!2. ;... ;... ;... ;... LU
;:::- ;:::- U
;:::- J: J: N N oci "" Z
J: CJ CJ ~ - ~ ~ 6' :>
CJ UJ UJ W W W W LU 0
Z Z
UJ J: J: --' --' --' --' 0 U
J: CJ CJ CJ CJ z z
0 0 z z z z 0 LU ~ <(
0 <6 oci (i2. (i2. (i2. (i2. 0 u z
<6 , , '!2. z 0 0
- ;... ~ ;::
~ ;Z [i) [i) [i) (L --'
e. ~ t::. '" --' U
LU LU LU LU <(
[i) [i) [i) Cl. Cl. Cl. Cl. :J 0 :J
f- --' (f) '"
W LU LU ~ ~ ~ >- LU --' :a: f-
Cl. Cl. Cl. t::. u <( LU (f)
>- >- ~ LU LU LU LU Z CJ !:: z
t::. t::. f- ~ f- f- <( Z 0
<( <( <( :a: i'i': >- u
CJ CJ CJ CJ CJ CJ CJ '" LU ~ >-
z z Z LU LU W LU 0 Z f-
(3 (3 (3 u u u u (L f- 0 Z
Z Z Z Z Z Z Z '" '" <( :J
LU LU LU LU LU LU LU LU ~ 0 0
(L (L (L (L (L (L (L Cl. '" U
0 0 0 '" '" " <0 0>
0 c:; N " ~ c:; c:; N ~ 0 6>- 0>
N N N 0>
Z 6 6 6 6 6 6 6 0 :Jl3: d,
6 "
E ~ ~ <0 "' <0 "' U UO 0>
~ 6 6 6 6 6 6 6 I'- m
"' '" '" '" "' "' '" '" u u'" u
"' '" '" '" "' "' "' u
..
..
'C
..
c;,
-
CI>
>
LU
S
~N~
~1:~
cAQ)-
oE~
o Cl 0
- .. E
In'''g
'C
..
o
~
0;
;;:
<5
o
o
o
o
o
..:
"'
~
~
'"
0 0 0
0 0 0
0 0 0
'" '" '"
"' 0 "'
m " ....
0 "' N
""
(L >- >-
(f) u u
Q) :0
" '"
~ on en
~ tl
'" '" .c
:;: ~ u
tl <;; '"
'" '" Q; 0
0 Ci
0 ii5 Q.
~ Q.
Z '" '!2. ~
CI> ,~ ."l CI>
'" <;; Qi
-0 'x CI>
~ LU U U
'0 r:: r::
0 0
ro ro u U
r:: - -
'" > - -
u 0 on on
E on on
r:: CI> '" '"
'm '" (3 (3
:a:
CI>
ro
CJ 0
c " ,
CI> '" c;. N
-0 6 6
(5 0
~ 0 0
CJ ~ " "
..
o
..
--'
~ '"
0 LU
f- ~
>- :>
~ f-
U
0 :>
<( ~
0 f-
~ '"
=
>- >-
0: 0:
0 0
Cl Cl
LU LU
f- f-
<( <(
u u
~
"
"
::>
o
z
UJ
o
o
<(
..
"
'tl
..
C,
~
..
>
w
.s
.... -0
..N~
~~C1J
en cu..9:!
oE~
C '" 0
- " E
"''''g
'tl
..
o
~
Q;
s:
6
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" 0
0
0
'"
'"
~ '"
0
I-
0
0
0
0
" 0
u 0
.~ '"
a. '"
~ '"
'E
:J
'" '" '" ;:; '" .... '" 0 '" 0 0 "' 0 0 N '" '"
;;; '" ~ N 0 '" <0 '" N N N 0 0 0
"'- '" "'- <0 0 '" '" '" '" '" '" ~ 0 ....
~ ~ 0 :; '" N- "" N
'" <0
a
~ >- >- "- <( "- >- >- z z
'E '" '" <Xl "- "- "- "- "-
:J 0 UJ 0 --' --' --' --' --' w --' --' UJ --' --' 0 l- I-
.....
l:: ;;;;
0 -
'" d ~
Co UJ
'5 a;- U"
0 '" Co :g
" ~ '" '"
C l:: .c "-
UJ
E aJ u:.
> U" ~
~ is N "" :g u::
"" '" "" '" '"
- <Ii "- aJ
" d ~ ~ "
aJ 0> =>
.c UJ " 0> 13
~ :ii '" '" ." ro ~ ~ u:: e-
a;- '" ~ "u
a;- '" '5 ~ .. "" '"
'5 => aJ .~ aJ aJ
tS '5 en "- l:: "- ~ " w
:g. ~ 0
tS 2 tS .c - 0> aJ rn aJ => .c 0
2 '" u - > t:- 13 13 Z
-:;; " -:;; 2 '" aJ ~ d 2 <Xl >- e- UJ ~
'" Q; -:;; 0 0. 0: 0> aJ U ""
.0 "- 0. >- t3 0> ill
=> 0> 0. .0 !::. - "" ~ ~ c '"
aJ => => "- aJ l:: 0
~ c W u " 0 aJ C
"> C ~ ~ ~ '" E .. "iii "iii W E '" --'
.. E t3 ~ 0 <Xl --'
.. 0 0. a; a; a; '" .c '" "- aJ <(
W 0 '" l:: C '" .1i1 0 u '" u <Ii
i5 0 aJ aJ .. aJ 0 "" UJ
t3 .. U5 U5 U5 <Xl U >- '5 s ;; ;;0 rn -6 :0 aJ W
c Z 0 rn '" "- C .0 C
0 0 0> 0> 0> " " - "- <Xl .= '" => 0 '"
u 0 2 c c c .. aJ "0 '" E "- c UJ '" U5 ::J
u:: "" "u T~ '2 '" '" '" 2 .. aJ .~ I-
~ '" '" => UJ 0>
0 0 ~ ~ 0 0: c W -:;; ci: ci: c 0
.. "- 0 .2 --' u t3 i" i" ::J
'" 0> C c E ;;0 aJ i5
'" :g E c '" '" -:;; -:;; l:: " "- "- "0 '"
'" 0 "w "w "w i" aJ .. .. => '" 0 aJ aJ I-
0 cD 0 '" '" ~ "- 0: l- I- ;;' .= u "- 00 00 <Xl UJ
0 .1-
'" 00
z .... '" .... M '" ~::J
<0 1" "1 q> -+ 0 '"
E -+ '" '" '" 0 0 <9 M '" U ~
~ '" ~ ~ ~ '7 .... .... ~ ....
0 6 0 J, J, J, 0 <0 J, J, 0 0 N N 6 0 0 oti
0 0 0 :; :; :; <0 <0 <0 co '" N co co co
'" '" '" '" '" '" '" '" co co co co co co
'"
o
'"
M
"
"
::>
Cl
Z
LU
Cl
Cl
..
~
';:
Uj' :J
~-
..
c;,
~
..
>
W
S
~N~
~1:Z
mQ)-
oE~
0'" 0
- .. E
Cll"'g
'C
..
o
~
a;
;:
o
-
-
-
]
o
I-
o
o
o
o
o
<i
"'
M
...
..
"
."
a.
~
';:
:J
~
o
"
.S!
E-
~
~
~
o
E
~
..J
<(
I-
a
I-
"'
W
~
:J
l-
t)
:J
~
I-
"'
=
~
a
Cl
w
!;c
t)
.;
z
E
~
"'
Cl
z
52
~
<(
:;;
I-
Z
W
:;;
W
::;:
a.
o
z
<(
Cl
z
Z
Cl
u;
0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '"
'" 0> ... ~ " " <0 0> 0 0 0 ,~
N " ~ <0 ;;: ;;: 0
~ ... N
N
(/) (/) <( <( ~ <( <( <( LL LL LL /1;;
<( <( w w w w W ..J ..J ..J
5"
<(
0
a:
LL
0
0 w
Z ::J W
t=' t=' w ..J W
t=' (/) W W ell ::J l-
(/) ~ ..J
0 0- > ell I
iL (/) a. 0 >- f= 0 ~ ~
0 0- !::. 0 ::s
(/) 0- W , 0
N ..J ~ 5" w ell ::s w
w CJ ..J
..J W LL W ~
Z :J I- ell (/)
Z CJ ~ 5 z w !:: W 0
<( iL z ::J a: I 0 !:: z
I ..J
l- (/) (I!. w W I- 0 0 ~ ..J I 0
:;; a: w z
(f) "' W I- !;c Z I- 5" C ~
(f) N > <( ::J I- w ::s
w N 0 0 0 (/) a: :J a:- a:- g
"'- - :;; 0 0 w 0 I- 0 ;Z ;Z
..J ..J ..J "=- (I!.
l- I- w w w CJ z (I!. (I!. I-
(f) (f) ~ ~ ~ z a: w 0 z
0 0 (jj w :;; f= w w ~
0- 0- Z Z Z '" W 0- 0-
W w <2 CJ CJ ri a: ~ (/) 0: 0:
::s w
..J ..J (f) (jj (jj 0 <( l- I- >
CJ CJ CJ CJ CJ ~ :;; 0- W (f) f=
z z a: 0 u u
(jj z z Z I- W :;; u:: u:: u
(f) f= f= f= 0 w
Z Z Z W '" a: LL LL ..J
(/) (/) (f) :J ~ a: w ~ <( LL
CJ CJ X X X W ell ~ I a: w
(jj (jj w w w 0 0 l- I- I- a:
N ~ (::j N " ~ ;;
6 6 ~ N ~ '" ... 0>
J, J, J, ~ , J, N N
J, 0 J, "'
" " 'f 'f 'f 'i' 'i' 6 6
6 6 0 , 0
0 0 0 0 0 ... "' ... 0 0 ;:: ;::
... ... 0 0 0 0 ;:: ;::
... ... c-- c--
m
o
~
>-
~
a
Cl
w
!;c
t)
~
..
'"
::>
o
z
w
o
o
'"
Vi'
..
"C
"'
C.
~
..
>
w
.s
&;N~
"'-..
on " ..
c:>>G.l-
oE~
0'" 0
- .. E
lll"',[
"C
"'
o
a:
a;
;;:
i5
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
c:i c:i c:i c:i c:i c:i c:i c:i c:i c:i c:i c:i c:i c:i
'" '" '" '" '" '" '" '" '" '" '" '" '" '"
]
0
I-
..
u
."
a.
-
'c
:J
.. gj '" ~ "' c; '" t- O i~ ...~ N " "' '"
~ '" 0 <D 0
0> O. "- '" ~ 0>
~ -<i ~ ~ '"
a
- .....~ :;; :;; :;; ":J <C <C :;;
'c u.. u.. u.. u.. u.. u..
:J Z Z ..J ..J ..J Cl ..J ..J W W Z ..J
.
" (e. ...~
0
., (j)
0.
"5 w
(e. z .. ~
~ ~ (e. :J
.. w J (j)
0 0 N "' " iL iL 9 w (j) (e. (e.
E ..J (e. (e. ~ ~ ~ 52 52 :J Cl 3: 0- 0-
,1! ..J (f) <C
UJ 0- 0- 0- 0- 0- (f) Cl (f) 0 :J :J
C. 0 ;;:
:J :J :J :J :J ~ " " (f) a: 0 0
w 0 0 0 0 0 0 - - e UJ a: '!!- '!!-
(f) '!!- '!!- '!!- '!!- '!!- ~ e e ~ e. :'S- ~ ~
0 w w w w w w w w 0 w w 0 0
Z l- t: t: t: l- t: t: t: ..J t: I- ..J ..J
0 I I I I I I I I ..J I I ..J ..J
Z ~ ~ ~ ~ ~ ~ ~ ~ w ~ ~ UJ w
:"i c. c. c.
g 0- 0- 0- 0- 0- 0- 0- 0- 0- 0- 0- 0- 0-
l- I- l- I- l- I- l- I- l- I- l- I- l-
I- '!!- '!!- '!!- '!!- '!!- '!!- '!!- '!!- '!!- '!!- '!!- '!!- '!!-
z () () () () () () () () () () () () ()
;;: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;::
Cl. (f) (f) (f) (f) (f) (f) (f) (f) (f) (f) (f) (f) (f)
w :"i :"i :"i :"i :"i :"i :"i :"i :"i :"i :"i :"i :"i
>
;:: Cl. Cl. Cl. Cl. Cl. Cl. Cl. Cl. Cl. Cl. Cl. Cl. Cl.
() 0 0 0 0 0 0 0 0 0 0 0 0 0
w :;; :;; :;; :;; :;; :;; :;; :;; :;; :;; :;; :;;; :;;
..J a: a: a: a: a: a: a: a: a: a: a: a: a:
u.. w UJ UJ UJ UJ UJ UJ UJ UJ UJ UJ UJ UJ
W I I I I I I I I I I I I I
a: l- I- l- I- l- I- l- I- l- I- l- I- l-
e 9 ro N ro ;: ;: '" ;;; ~
0 ~ '" , <? 'f "'
z '" t- ,c ,f, ,;, ,f, <? , "! 0\> de, J:,
2> <? <? ~ ~ <? <?
E <? <? <? ~ ~ ~ ;:: ;::
,1! ;:: ~ ~ ~ ~ ~ ;:: ~ ;:: ;:: ~ ~
;:: ;:: ;:: ;:: ;:: ;:: ;:: ;::
~
"5
ro
M
..
:;
::>
"
z
UJ
"
"
"
" "
" "
0 0
.. "
"
'"
~ ..
0
I-
"
"
0
"
'" "
" ",-
.;: ..
0-
~
.~
::J
a;
"'
~ <'i
a
~
.~ "-
::J ...J
"
0
"' W
0.
.;: 0
" z
.. ~
'" Co
0 ~
E 0
6' ...J
~ ...J
:i <(
0 en
'!!- Cl
~ z
;z
0 '"
...J <(
...J :;;
W
C- I-
6' z
w
I- :;;
'!!- w
0 >
<(
i= 0-
en 0
:S z
0- <(
0 Cl
:;; ~
'" z
w Cl
I
I- en
a; :;;
ci 0-
en
z ,;, 6
E '? '"
~ ~ '"
0
"- 0
..
'"
'0
..
C,
~
'"
>
w
o
~
toN~
"'~'"
"1" '"
","'-
oE~
o Ol 0
- '" E
alOl,[
'0
..
o
'"
a;
;;:
o
o
o
d
o
o
.,;
~
'"
" " " " " " " " " "
" " " " " " " " 0 0
0 0 0 0 0 0 0 0 0 0
.. .. .. .. .. '" '" .. '" '"
0 "' 0 ...~ " <Xl " a; .:;; N
~ N " N r...; "
"- ~ '" '"
~ .~ N c5
N
"- "- "- "- "- ..~ a: "- <( ifi
...J ...J ...J ...J ...J ...J W
G:i U
6' 6' g i=
e:- o "-
iD z z z 0 0
:::> ::J :::> :;; m
z 0 0 0 --' '"
<( '" --' --' w
I N '" :;; Cl :::> m
l- V Cl Cl w en ~ g;
w '" Cl <5
en 0 > w
en I- 0 0 0 :::> ;;; ;;;
w m z i'2 !oS !oS
...J iD ~ 2- ~ rr
<{ <{ "- en en
0 w w
e. e. ;;; ;;; ;;; "' x x
w w !oS !oS !oS ,;, 0 0
;;; ;;; N m "'
'" '" en en en
0 0 --' --' ...J !oS !oS ;;; z z
"' "' <( <( <( 0 0
z z z --' --' !oS i= i=
...J --' ~ Cl Cl <( <(
<( <( z Z I- 0 0
z z en en en Cl Cl "- z z
0 0 t: t: f-' en en 0 :::> :::>
i= i= '3 "' , ,
:::> :::> W W "" ""
0 0 0 0 0 u::
w w z --' --' --' --'
z z m m m --' --'
'" '" 0 0 0 <( <( <( :::> :::>
0 0 0 0 0 0 0 0 "- "-
'i' ~ N '" 'i' '"
, , ~ ~ ,;, r-C N ~ ~
,
,}, ,}, ~ ~ N N ~ ~
6 6 6 , ,}, ,},
'" '" <0 <0 <0
'" '" <0 <0 <0 '" '" <0 <0 <0
'" '" '" '" '" '"
..
o
m
...J
<(
I-
0
I-
Ol
Cl
z
2
'"
<(
:;;
I-
Z
W
:;;
W
~ Z
0
0- >=
"" ;5
Cl :J
z <(
Z z
Cl Cl
u; u;
I
- ;::
~ ~
0 0
Cl Cl
w w
~ I-
<(
U U
M
"
"
::>
o
z
w
o
o
'"
-;;;-
"
'"
..
c;,
~
~
W
S
&;N~
~~g:
c:Al>>-
oE]!
C '" 0
iiiclll
'"
..
o
0::
~
<5
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,; ,,;
'" '" '" '" '" '" '" '" '" '" '" '" '" '"
~
0
I-
"
"
."
0..
-
.~
::J
.,. 0> "', " N '" ~ "' ]j 05 0 0 '" '"
0 ~
>- N-
I-
a
,','
- rJJ <( <( <( <( <( <(
.~ "- rJJ rJJ rJJ rJJ rJJ rJJ
::J <( -' w W w w w w <( <( <( <( <( <(
i2
l- I
z
0 I-
0 '-'
z
>- w
!E. -'
Ei' OJ
~
z Z ~
::J ~
c: 0 w ~
0 0:: 0.. ~
~ '-' ~ GJ GJ
0:: ~ I- Ei'
." w <( ~
" 0 z 0 w Ei'
..
" z 0 ;;; ;;; ;;; ;;; ;;; 0 0 "'-
C 2- "- -' -' w
~ ~ ~ ~ ~ ~ ;;; ;;; w w Z "'-
E en - N '" ;t z ~ ~ ~ ~ s z
~ -' ;;; U? '-' 6' 6' 0
<( rJJ rJJ rJJ 6' 6' S
z ~ <h ,;, <h Uj w w w w 0
0 "'- "'- I- 0
'-' rJJ 0 0 0 w "'- -' z 0
~ w :i; :i; :i; :i; C ~ ~ ::J I-
;;; --' -' ~ <( ~ ~ 0 z
w ~ 0 0:: 0:: 0:: 0:: <( S ~ <( ~ ::J
0 0.. <( <( <( <( u s 0
:> w w --' -' -' -' w ~ ~ ~
0:: '-' '-' '-' '-' 0.. , , ~ ;;;
0:: s: l- I- ~ ~
w w ~ ~ ~ ~ ~ I- ~ =
rJJ 0:: 0 0 0 0
w 0 >- >- >- >- >- w w w W rJJ rJJ
0:: 0 Z --' -' -' -' -' rJJ rJJ rJJ rJJ -' -'
w :> 0 '" '" '" '" '" C ~ C ~ <( <(
s :;;; :;;; :;;; :;;; :;;; z Z
0:: 0 W W W W W --' -' --' -' '-' <:2
0 w 0 rJJ rJJ rJJ rJJ rJJ <( <( <( <( Uj
0.. rJJ W rJJ rJJ rJJ rJJ rJJ Z Z Z Z rJJ
--' -' rJJ <( <( <( <( <( <:2 '-' <:2 '-' z z
<( <( rJJ :;;; :;;; :;;; :;;; :;;; rJJ Uj rJJ Uj <( <(
0 0 w ii' ii'
ii' ii' 0:: 0:: '" 0:: '" 0:: 0 0 0 0 l- I-
l- I- I- <( <( <( <( <( u: u: u: u: rJJ rJJ
0 0 rJJ l- I- l- I- I- "- "- "- "- w w
w w W rJJ rJJ rJJ rJJ rJJ <( ~ ~ <( 0 0
-' -' '" <( <( ~ <( <( '" '" w w
w W 0.. :;;; :;;; :;;; :;;; l- I- l- I- 0.. 0..
" 0 N '" .,. 0> ~ ~ ~ ~
0 N ~ ~ 0 0 0 0> ~ in a;
"! ~ ~ ~ ~ ~ '7 "' '"
z r;. , , , .;. .;.
:;; :;; ~ :;; in in ~ '"
E ill '" , "' "' "' "' <h <h
~ "' '" d> d> d> d> d> 6 6 6 6 "' "'
'" '" :;: .,- .,. .,. .,. .,. "' "' "' "' '" '"
'" '" '" '" '" '" '" '" '" '"
..
'0
o
M
"
:;
::>
o
z
w
o
o
"
..
"
'C
..
C,
-
"
>
w
.s
t;N~
~c::
","-
cE~
o tll 0
- " E
1Il"',g,
'C
..
o
0::
a;
s:
o
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '"
]
0
I--
"
u
.~
Q.
~
'c
:J
..~ g on 0 '" ..,. ..,. <0 '" ..,. N ..,. ..,. ..,.
~ ~
~
0
>.
~ " " " ;:'j ;:'j " ...~ Lii " (f) Lii ;:'j " "
'c
:J W W W W W " W W
.
.... ;;0
~
~ ;;0 ill ;;0
w ~ = 0
I-- OJ .0 ;;0 It ~
(f) '" '" ~ ~
:J 0 6 I '"
-' " 0 w w
i=' ::; 0 ~ a: ::;; I-- I-- 0
I-- w :::: ~ 0
~ 0 ;:: 0 oil oil Z ~ ::;;
.g w =
w ..,. ..,. w (f) (f)
c. (f) (f) (f) ::; 0 0 >- z (f)
<0 w ,;, ;:: ::; ,;, ,;, -' I '" 0 '"
.~ ~ 0 " N N OJ (f) W U-
u en w (f) '" 0 cL cL ::;; :"i ::;; F
.. 6
" w 0 0- W w F I-- t;: W U- F "
0 I-- (f) ::;; I-- 0 0- U- (f) '" F
S :> :"i w Q. ~ ~ (f) ~ ~ Z 0-
E :J 0- " W W ::J 0
l! 0- -' Z 0- '" 0- 0-
'" W ~ '" ::;; ;;0 I-- I-- w ~ >- ::;; '"
Z ::J Z Z ::;; w
0 Z ::J 0 ~ ;;0 ::J ::J -' C- o OJ
" -' " z ~ 0 0 -'
~ ::J ~ ~ ~ (f) 0 ;;0 ;;0 2- g;,
c- w >- ::;; ::;; '"
;;0 ;;0 ;;0 ;;0 ::J :::; -' w W I-- ~ ~ I-- I--
-' OJ OJ -' -' z z z
~ ~ ~ ~ :'S ::;; (f) (f) w
::;; 0 0 0 w w w
(f) (f) (f) (f) (f) w W 0- 0- 0 ~ ~ ::;; ::;;
w w w w w (f) (f) '" '" 0- 0-
~ ~ ~ ~ ~ (f) w 0 0 :;
(f) " 0 0 I-- (f) (f) ::J
" " " " " " I-- I-- ;:: (f) (f) a a
:::; :::; :::; :::; :::; '" z 0 0 w w w w
X X X X X 0 0 w w (f) 0 0 -' -'
::J ::J ::J ::J ::J I-- F I-- I-- 0 0 0 0 0
" " " " " 0 0 w w :::; " " '" '"
w w 0 0 0 I-- I--
0 0 0 0 0 f-- f-- Z Z (f) '" '" z z
" " " " <( w w <( " w w 0 0
w w w w w 0 0 0 -' -'
I I I I I ~ ~ w -' -' 0 0
w w f-- f-- ~ 0 0 ::;; ::;;
-' -' -' -' -' -' -' (f) (f) '" '" w w
<( " " " <( '" '" I-- f--
Z Z Z Z z w w ::J f-- f--
CJ ~ (9 CJ (9 I I 0 0 !- Z Z (f) (f)
w w w w 0 0 0 >- >-
1i5 (f) 1i5 1i5 1i5 > > 0- 0- <( 0 0 (f) (f)
,; co r-- ~ on 0 on r-- <0 <0
0 <0 r-- ~ ~ ~ 0 0
0 0 ~ 0 .j- .j- '" ~ 0 ~
z ~ ~ '" , ,;, <\> , ~ ~
E , en en , en ';- r-- on 6 6
m m <0 <0 <0 ro ro
" on '" '" on on '" <0 <0 0 co co
'" <0 <0 <0 <0 <0 <0 <0 r-- r-- r-- <0 <0
<0 <0 <0 <0 <0
m
15
;:
~
"
"
::>
C>
z
UJ
C>
C>
""
en
a>
'C
~
Ol
~
a>
>
UJ
.s
.... -c
."" '"
'" - a>
"''' a>
d,CD-
oE'=
COlO
inJ;!
'C
..
o
'"
Qi
:;:
i5
'" '" '" '" '" '" '" '" '" '" '" '" '" '"
'" '" ~ '" '" '" '" '" '" '" '" '" '" '"
0 0 '" 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '"
]
0
I-
a>
u
;t
-
'"
::>
..,. f' ..... <:) ..f::l <0 ..,. g ..~ N ~ N <0 N '"
~
.
~
a
i
- <( <( <( <( <( <( <( <( <( <( <( <( <( <(
'"
::> w w w w UJ w w UJ w w w w w w
GJ Z
0
0 F
'" <(
::J 0
0 ):' z
(/} ...J ::>
0:: III 0
W " "-
" ~ w (/}
.!l (/}
C. 0 (/} (/}
o. '" <( UJ
'C (/} ;::- ~
u UJ "- W
.. ...J Z I- ):' >-
a> III ):' ::? w
f': >- " w (/} ...J
C ...J 0 ...J III
E III 0:: ...J >- :r: o. (/} "
o. " III ...J ::? 0 " <( >-
~ :0 t- " ...J W
W Z III <( ~ 0 t- III (/}
0:: (/} 0 w " '" S!- w " (/}
0:: (/} 0 (/} w z w <(
w <( (/} (/} ::J <( in
t- ...J <( III >- (/} z
(/} Z ...J ~
'" ~ ~ c <( t- o III (/} <( >- C)
<( 0 " <( '" ...J Z
Z W t- Z ':J 0:: III :::;
2. w <( w w >- t-
" Z :r: ...J 0:: (/} (/} 0 (/} " III
<( W '" f': 0 0 (/} (/} t- W W <(
;;; S!- S!- ...J t- fl'l. <( <( 0 c (/} 0
<(
f':- z (/} (/} iL iL 0:: 0:: W W (/} C
;;; ;;; w W t- o. <(
(/} C) 0 0 w w w w w w z
UJ f':- "- 0; UJ W W W ...J ...J 0 0:: <(
...J ...J 0 0::
'" t- t- o o. o. ~ ~ 0 0 w ~ !::
t-
<( Z z LL ...J ...J ...J ...J 0:: 0:: ...J 0 ::J
:::; W W "- <( <( 'ii 'ii t- I- ~ W Z 0
X " " <( z z z z :r: t- g: Z
::J o. "- 0:: C) ~ 0 0 0 0 w w 0
<( :::J :::J t- o; (/} " " 0 u > 0 (/} u
" a a w w w w w w w w w w w
UJ w w > > > 0:: 0:: > > > > > >
t- f:: f:: 0 0 0 w w 0 0 0 0 0 0
(/} " " " ...J ...J " " " " " "
>- u u w w w 0 0 w w w w w w
(/} U U 0:: 0:: 0:: "- o. 0:: 0:: 0:: 0:: 0:: 0::
ci <0 <; ..,. '" '" N '" '" '" '" '"
z '" '" 'i' ;;:; "' "' "' 6 "i' f0- ro '"
~ 6 6 '" '" 6 "' 6 6 6
E J, J, J, '" 6 6 6 '"
'" '" '" '" '" '" '" '"
~ ro ro <0 <0 <0 <0 '" '" <0 '" <0 <0 <0 <0
<0 <0 <0 <0 <0 <0
m
o
N
M
..
"
OJ
Cl
Z
ill
Cl
Cl
<(
0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" 0
0
"'
<'">
:s '"
0
r-
0
0
0
0
" 0
" "'
." <'">
"- '"
~
'c
::>
<'"> ...~ <'"> ~ ~ .... ...~
.....
~
a
~ <( <( (f) (f) (f) <(
'c (f)
::> w w <( <( <( <( w
"
0
'"
a.
"5 r-
.. Z ;=-
" w Z
0 :2 ;=- ::>
E 90 Z 0
~ ::J ::J :2
0 0
:2 0
w <(
-" 0 w
<( w- Z I
Z :2 ::J '"
~ '" '" 0 w (f)
<( w w '" > w
(f) Z > > ~ Q U
(f) r- w w V Z
::J ~ -" -" Z Z ~
0 i= i= '"
:2 0 0 0
w Z Z U U
Z ::J <( <( <( <( '" 0
::; --' U U ~ --'
=! w w -"
--' 0 0 en en ;;0 <(
w --' <( <( CJ CJ Z
U <( W W ~ ~ ~ 0
(f) Z I I
'" '" '" I I --' i=
~ w w w (f) (f) w ;S
W I- > > ::; ::; Z
> ~ 0 0 <( :::;
"- "- "- <(
0 z z Z
:2 Z Z Z Z
W CJ CJ CJ (9 (9 (9 (9
'" in in in in in in in
~ N ~ N a)
ci 0 ~ '--'
~ ~ g<(
z 0 , '" 0 , ro
0
, d, <'"> "I ill 1" illZ
E 0 N N 0 '(9
!!! ill ill 0 0 0 0 U_
'" '" 0 0 0 0 0 U(f)
I'- I'- I'- I'- I'-
..
"
"0
"
c;,
~
"
>
w
o
~
roN~
"'~"
"'''"
cAQ)-
oE]!
g ~ OE
<0"',[
"0
"
o
'"
a;
:;:
(5
...J
<(
r-
o
r-
z
o
i=
i5
::;
<(
z
Cl
(jj
~
>-
0::
o
Cl
w
!;;:
u
o
o
C
o
o
.,;
<'">
..
0 0 0 0
0 0 0 0
0 0 0 0
'" '" '" '"
0 0 N <'">
I'- ill ...
'" ill
'" "'"
... ~
"- "- <( <(
--' -" w w
(9 S
Z ...
i= I W-
I U
(9 (f) (9
:::; U ~ 5'
<D > Z
e:- o i=
0 0 > I
;S >- (9
Z '" ~
0 ::J <(
W 0 0 W-
I- '" Z 0
::; (9 0 in
::J '" U 0
(f) w w <(
0 g
Z Z 0
"" ~ ;;0 ~
;;0 "- ;;0
~ ;;0 '" ~
'" ~ w (f)
0 t: r- w
r- ::J Z ~
U 0 W
::J Z U en
0 0 0 --'
Z U <( --'
0 0 ::J
U N --' "-
N ~ ~
, ~ ~ ""
~ N '"
,;, ,;, ,;, ~
,;,
r:. r:. r:. r:.
~
a
M
Cl
z
i=
:I:
Cl
::;
:>
>-
0::
o
Cl
w
r-
<(
u
~
"
"
::>
c
z
w
c
c
'"
0 0
0 0
0 0
'" 0
0
0
J! a
0
t-
o
0
0
0
.. 0
" 0
." "
a. '"
~
'c
:J
<0
'"
~
a
~ <(
'c
:J W
i='
I
C)
Uj
I
C)
2
;::
2
:J
0
2
b
~
Z
C)
u;
W
0
" --'
0 <(
;l 0
0.
." W
" a.
U> (f)
.. ~
0
E :J
2
~ ~
::J-
--,t-
<(2
_:J
""0
::"2
-",
Ww
t-o
W--,
--':J W
0..0 U
2I 2
O(f) ~
u2
~'" 0
--'
0<( --'
o..N <(
C)~ C)
2W 2
---' ;::
t-C)
I2 I
(9- C)
::::;(f) ::::;
0
ci " at-
,
2 ~ "'I
E U; "iC)
u-
~ "' u--'
;::
"
..
"C
..
0,
~
..
>
W
.s
~N~
N~..
"''' ..
mCD-
oE':
C '" 0
- .. E
lIl"'g
"C
..
o
'"
Q;
;;:
o
0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 g 0 0 0 0
'" '" '" '" '" '" '" '" '" '"
.
0 '" '" 0 ..,. N '" .... ~ '" N
.... " " C; .... ~
~
'" ",-
N ~
LL LL LL LL <( <( <( LL <( <( <(
--' --' --' --' W W W --' W W W
~ ~ ~
u; u; u;
0.. a. 0..
0 0 0
'" '" '"
~ ~ ~
w w w
!;;: t- !;;:
<(
~ ~ ~
g g g
., ., .,
~ ~ ~
'"' iJ) iJ) iJ)
'"' .-- '"' w W W
en en 0- 0- 0-
en '" cri " ~ ~ ~
-.i "' '"
~ '" ~
, , cri , ,-- --' --' --'
--' --' --'
b b b ~ b '" <( <( <(
('oj ~ :5 , cri
~ (f) (f) (f)
?5 b ~ '" '" '"
'" '" '" 2' '" , W W W
W W W w b > > >
s s s S N U ~ 0 0 0
W W W 0 ~ ::J U U U
(f) (f) (f) III 0 W W W W
iY iY iY --' --' W W (/) (/) (/)
W W W ~ <( ~ ~ <( <( <(
t- !;;: t- O w W W
<( [ ~ W ~ ~ --' --' --'
en ~ ~ 0- W W W
W ~ g ~ ~ '" '" '"
;:: u u G '" '" '"
::; > > > ", ., ", ", ;;:: ;;:: ;;::
;:: ~ ~ ~ ~ 1'; ~ LL
ilJ >- >- >-
:J ::::; ., (/) (f) (f) --' --' --'
", ", C) (9 C) C) III III III
:> ;!i LL !:: LL 2 2 2 2 2 2 2
W W W ~ ~ ~ ~ W W W
>- 0 0- 0- 0- (/) (/) (f)
'" 2 a:: a:: a:: u: u: u: u: (/) (/) (/)
0 w <( <( <(
el ~ >- >- >- ~ i':: i':: i':: W w W
t- t- t-
W W ::::; ::::; ::::; ::::; ::::; ::::; ::::; > > >
t- --' --' --'
<( a. ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;!i ;!i ;!i
() a:: ::J ::J ::J ::J ::J ::J ::J
N '" " " ..,. " ..,. ,
N N N l' '" '" N "- ,
"1 "1 "1 "i 1" 1" ~ ~
0 ~ ~
~ ~ ~ ~ ~ ~C-- ~ <0 ~ '"
N ~ ~ ' 0 '0 ' 0
, 0 , ,}, , ,}, ,}, :2N :2N :2N
0 0 0 u;
~ u; '" u; u; u; '" '" 0 0 0
0 0 0 0 0 0 0 ~ ~ ~
~ ~ ~ ~ ~ ~ -
o
o
o
o
o
o
"
'"
w
a
v
..J
<(
t-
o
t-
el
Z
;::
I
el
::;
>
>-
'"
o
el
W
t-
<(
()
M
"
"
::>
o
z
UJ
o
o
""
"
Ol
"0
"
C,
~
Ol
>
W
S
t;N~
~~~
chQ)-
oEl:
oOla
- Ol E
<l]"'g
"0
"
a
a::
Q;
3:
(5
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 ci ci ci ci ci ci ci ci ci ci 0 ci ci
'" '" '" '" '" '" '" '" '" '" '" '" '" '"
:s
a
f-
Ol
"
.;:
0..
-
'c
::J
v <X> N N N ~ I"- "' "' "' 0> <X> ~ ~
~
0
- <( <( <( <( <( <( <( <( <( <( <( ~ <( <(
'c
::J W W W W W W W W W W W W w
b N '" ~ ~ b N (0
~ ~ ~ ~
(f) en en (f) en en en en l1J l1J
0.. a. a. a. a. a. a. a. (f) (f)
0 0 0 0 0 0 0 0 ~ ~
"' "' "' "' "' "' "' "'
~ ~ ~ ~ ~ ~ ~ ~ --J --J
[jJ [jJ [jJ C3 C3 C3 C3 C3 l1J l1J
a:: a::
~ f- f- :::> :::> :::> :::> :::> a:: a::
<( <( --J --' --' --J --J
~ ~ ~ ~ ~ ~ ~ ~ ~ ~
~ ~ ~ ~ ~ ~ ~ ~ ~ ~ N
~
;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; 12
"=- "=- "=- "=- "=- "=- "=- "=- "=- "=- l1J
C if) if) if) if) if) if) if) if) if) if) a.
a ~
'" l1J l1J l1J l1J l1J l1J l1J l1J l1J l1J :::>
Co a. a. a. a. a. a. a. a. a. a. a.
"ti ~ ~ >- ~ >- >- >- >- ~ ~
f- f- f- f- f- ~ >-
~ --J --J --J --J --' --' --' --J --J --J W --J
Ol --J --' --J --J --' --J --' --J --J --J ([l
0 <( <( <( <( <( <( <( <( <( <( (f) ~
0
E (f) (f) (f) (f) (f) (f) (f) (f) (f) (f) I l1J
!! a:: a:: a:: a:: a:: a:: a:: a:: a:: a:: (f) >-
l1J l1J l1J l1J l1J l1J l1J l1J W l1J ~ (f)
> > > > > > > > > > 0 <( --J
([l
0 0 0 0 0 0 0 0 0 0 f- >- " ~
0 0 0 0 0 0 0 0 0 0 ~ --J 0 W
W W W W W W W W W W ([l w (f)
(f) (f) (f) (f) (f) (f) (f) (f) (f) (f) ;;;; ~ I (f)
<( <( <( <( <( <( <( <( <( ~ "=- w 0 <(
W l1J W W W W W W W (f) a:: a::
--J --J --J --J --J --J --J --J --J --J >- (f) 0 w
w w w W l1J W W l1J W W --J <( f- f-
a:: a:: a:: a:: a:: a:: a:: a:: a::~ a::~ ([l
a::;'" ~t'! ~ a. 0 w
a:: a:: a:: a:: a:: a:: a:: a:: ;': w ~
~ ~ ~ ~ ~ ~ ~ ~ ~g ~g w f-
(f) w a::
>- >- ~ >- >- >- >- >- ~a. ~a. (f) l1J 0 W
--J --J --J --' --J --J --J <( --J f-
([l ([l ([l ([l ([l ([l ([l ([l ([l0 ([l0 f- a. ~ ~
~ ~ ~ ~ ~ ~ ~ ~ ~"' ~"' z ~ w
W l1J l1J W W W W W w~ w~ t2 <( f-
(f) (f) (f) (f) (f) (f) (f) (f) (f)e;;: (f)- (f) (f) w
(f) (f) (f) (f) (f) (f) (f) (f) (f)--J (f)~ 0 a. >- --'
<( <( <( <( <( <( <( <( <(([l <(([l ~ (f) ([l
>- ;':
W l1J W W W W W W w~ w~ I w w
:oJ > :oJ > > :oJ > > >w >w w f- a:: 0
--J --J --J --J --J --J(f) --J(f) a:: t! u: a.
;; ;; ;; ;; ;; ;; <( ;; <((f) <((f)
> ><( ><( u: ~ '" "
N "'
.'- , ... ... ... ... ... 0 0 ~
ci ~ ~ N N
~ ~ ~ 00 00 '"
Z ~O ~ ~ ~v ~ ro ~ 0> ~ 0 ~'" ~ ~ ~
oN ' ~ ON ' 0 '0 o~ ON ON
E RN RN RN ~
!! l"- I"- l"- I"- I"- 6 6 ...
0 0 0 0 0 0 0 0
~ ~ ~ ~ ~ ~ ~ ~ l"- I"- v
0 0 <D
~ ~ ~
m
o
m
M
"
'"
::>
a
z
w
a
a
'"
-
Iii
0
I-
"
"
.~
a.
-
'"
:>
~
a
-
'"
:>
-
"
0
'"
Q.
.~
"
'"
"
0
E
~
ci
z
E
~
..
"
."
.!!!
'"
-
"
>
w
.9
f;;N~
"'-"
'" " "
cACIl-
oE'=
0'" 0
- " E
<llen~
."
..
o
a:
Q;
;;:
6
a
a
o
a
a
c:i
a
N
'"
a
a
o
a
a
c:i
a
N
'"
...J
~
0
I-
en
W
W ;::
0
Z ::;
~ ;::
:>
0 :>
...J
...J
<( >-
(f) a:
w 0
;:: "
::; W
I-
;:: <(
:> U
...J
;::
:>
6
co
m
0
0
o
o
ci
o
o
.;
o
N
...
a a 0 a
a a 0 a
0 0 ci 0
'" '" ... '"
N '" co
co a m
"'- m .,.
~ c:i "
'" '"
-
>- al "-
0 ...J (f)
C
Q)
"
'"
E
~
~
!!! !!! C
ro OJ en 0
$ $ -
w '"
'" a: ."
" '" :> "
" "
'c 'c I- 0
iij 'iij U "-
a; a; <( :> '"
a: a: c
a: S I- '6
-- en "
- a; "
'" Q) ~ u
'" = c
'" ii5 S =
<( (3 '" ;;: >- al
c a: OJ
S ,,- .e l'! 0 s $
.. a; " ..
" 13 .8 0 w " ."
- C :c I- - "
S c " "
0 'iii " <( - 0
;;: 0 OC (f) U ;;: (f)
!!! - '7 !!'. 0;
OJ N - OJ N
3 , 3
." 6 co D c-.
" a ~ c -+
" .,. " '"
0 0 co
(f) (f)
"
'5
"
en
w
I-
<(
Z
a:
W
I-
...J
<C
(')
""
:2 0 0 0 0 0
:::) 0 0 0 '=! 0
0 ci ci ci 0 ci
z 0 0 0 0 0
w 0 0 0 o. 0
0 Il'i 0 Il'i 0 ...:
0 CO 0 .... 0 0
<( (0. C') ~ 0 ~
.... ~ N N
~ ~ ~
~
0
<(
0
cr:
rJ)
<(
W
~
ll.
::i:
<( <( UI
U .., Q)
-
u. .., CU
0 0 I:
0 ..
I- (0 .sl
rJ) 0 <(
W
3: z UI
I- ::l
0 U a::
"-1-<( W - ;;:
coO'" ..., ..c
N<(_ 0 01 ..c
Il) I:
cAoQ) cr: ::l 01
ocr:E ll. 0 ::l
.. 0
Ow 01 >- ..c ..
-0Q) I- - ..c
al~rJ) Z -
UI
::J Q) UI
C> 0 .;: Q)
U 0 ';:
...J cr: (/J 01 0
...J E .sl 01
W W (]) cu .sl
3: :J :!::: U cu
...J >- U
...J 0 ell
0 U 0... <(
~ (f) .., N
0 (9 - -
I: I:
<( Z Q) Q)
0 ~ E E
cr: 0:: 01 01
...J <( Q) Q)
...J 2 rJ) rJ)
W l- I-
3: -I- Z Z
- (/J =z ::J ::J
...J ~ ~E ~w 0 0
0 o (/J 02 02 ::i: ::i:
OlE 01- ClW <( <(
Q) (]) Q) >- .sl;;:
tiS== - ell 0 0
cull. Jo...
U >- U(f) III III
_ ell -0
1:0... cW I:z W W
::l>- ::l0:: 5<( rJ) rJ)
0<( O::J <( <(
Es EI- E(9 III III
<(0 <(U <(z ...J ...J
-:J -z ~ <(
cu<( l!lo:: l!l(9 I-
-0 01- 0 0
~o:: 0-
I-(f) I-(f) l- I-
o
o
o
o
o
o
o
o
o
o
o
o
'"
..
:;;
:>
o
z
UJ
o
o
<<
-
c:
::>
o
E
<
'"
"
";:
l1.
-
'c
:J
C
<5
0:: 0; 0 CO CO
<0 ~ ~
'" <0_ ~
<C ~ ~
W '"
~ 0
l1.
::;;
<
() - <( U
LL 'c CIJ CIJ CIJ CIJ CIJ 0 LL LL LL ~ >- >-
0 :J --' --' --' --' --' en --' --' --' CIJ U U
I- --' --'
'"
W
:;:
0
"'1-<
"'0'"
"'<- ~
U:>OC:
~~~ -
0
OW",
mO",
~
Cl
--' I-
--' ::>
W a
:;: ~
--' c:
Q. 0 0
:;::l
0 c. Z CIJ W
.;: <( I-
< Z --'
0 " C9 ::>
OIl CIJ w
0:: " Z Z ::;; 0
--' 0 :5 >= ::> w
--' E w Z I
W 0.. > 0 u
:;: " 0:: CIJ 0::
"" f- ::;;
::> I- w 0::
--' --' CIJ >. U a:: -
6 ::> w w U w w C9
~ co z > --, u:: 0:: a:: 0.. z
a 0:: a LL <( 0:: >- m 0::
CIJ >= ::> 0:: ~ CD <( t:. :5
0 ;'C 0 CIJ 0.. ~ co co
<5 ::> I- w ::> ::>
z LL Z 15 ~ U 0:: C9
;;: 0:: a ;;: LL Z C9 w
0:: I- a m 15
CIJ z --'- w 0::
Z Z Z a z w --' 0:: co LL 0 I-
~ a <( a ~ <( u ~ ::> 0:: I- Z Z Z
>= ::;; u ::;; Z I- ::> --' <( a w
0 ;;S w w <( C9 I- Ui C9 ~ ::;;
Cl W 0:: Z 0:: Z Z 0<:
0 0 0 w w 0 0
w :J '> '> w '> I- a:: >= w w a:: z
?- m CIJ z <( 0<: 0<: <( <(
< a a w a 0:: a ~ ~ w 0 CD
() a 0:: 0:: 0:: 0:: <( <( --' --' x ::;;
::;; 0.. 0.. 0.. 0.. ::;; co LL CIJ CIJ 0 W W
0 ~ '" '" ~ ~
~ , , N ~ ~ ~ N <0 , - co
Z , ~ - , '" ... - - - 6 6
E , , , - '" ..;. ..;. ..;. 6
0 ~ - 0 0 N N
~ 0 0 0 0 0 0
0 -
-
o
o
o
o
o
o
o
o
o
o
o
o
o
o
'"
'"
:;;
::>
a
z
w
o
a
<(
~
l:
::J
o
E
<(
'"
"
.;:
0..
~
'2
=>
C
<!i r-- co
0:: "' r-- O'l O'l 0 O'l co "' co ~ ...
'" co r-- r-- co <0 '" co "' ~ ~ "'
'" co ... <0_ <0 r-- r-- '" <0 r-- ~
;;: ~ r--: m ... co) "' ci '" ci 0 co)
w ~ N N 0 ~ ~ '"
~ a ~ N N N N N
0..
::;;
<(
0 ~
u. '2 u. >- >- >- >- >- >- >- >- >- >- >- <( <(
0 => C/) C/) C/) C/) C/) C/) C/) C/) C/) C/) u u w W
I-
'"
W
~
0
.... I- <(
"'0 ...
&:l<( ~ 0
l: "' ~
'0 '" '" -
g:O::E ~ ~ 3 0
Ow", ~ N
N N --'
iDo", ~
~ N N
, ID
<0
Cl r-- r-- ~
--' '" 19 19 '>
--' ~ ~ ~
w <(
~ 5' 0' 5' 0::
19
--' l: U U U a::
~ 0 C/) u:: u:: u:: N 0
., W lJ.. lJ.. lJ.. N fS
0 Co "- <( r2 <( ID
<( .;: 0 a:: a:: r-- (jJ
0 " --' t:. t:. t:. 19 --'
<II C/) ~ --'
0:: '" ~ w w w ~
--' 0 --' ~ s ~ l- I- I- ID
--' E (5 0 ~ w w w
w ~ C/) "- "- "- a:: a:: a:: 0 (jJ 19
~ ::J ::J ::J U U u fS --' z
0 0 0 0 z z z --'
--' w "' <( z
(5 u a:: a:: a:: 0 0 0 s <(
a:: 19 19 19 U U U N S S
~ 0 I-
0 W W W U U U 0 I- Z W ~
lJ.. CD C/) C/) C/) f= f= f= z !O!. ~ ::!.- ::!.-
z w <( <( <( --' --' --' fS w
W "- f9. f9. f9. <( <( <( w :2 w w "' ID
a:: ~ I I I C/) W l- I- e::. e::.
"- "- "- ;;: w w
U --' --' --' C/) C/) C/) a:: a:: a::
f= z <( <( <( <( <( <( ::J "- U U ro ro
0 z z z 0
w 0 0 0 w w w z z a:: a::
I ~ f= f= f= ;;: ;;: ;;: u :i 0 0 ::J ::J
I- Z "- U U S S
z "- "- "- "- "- "- 0 C/)
>- :J 0 0 0 a:: a:: a:: f= <( C/) C/) C/) C/)
C/) ro w w w w w w U C/) C/) l- I-
0 <( C/) C/) C/) "- "- "- u :s :s w w
W I- <( <( <( ::J ::J ::J n:: C/) --' --'
19 C/) CD CD CD C/) (j) C/) lJ.. :2 U U ;;;:: Z
ci ... '" ... 0 ~ ~ ~
... 0 ~ ':' "' <0
~ ... 0 ~ ~ ':' N N ~ ~ '?
z , 0 r-- r-- r::: , , "- , ~ , '?
"' ,], ,], ,], ~ ~ O'l , ~ ~ ~
E , , ..;. "- co 0
... <0 ... ... '" , ,
CII co co co '" '" '" '" '"" 0 0 "' "'
~ N N N '" '" '" '" ... ... N N
... ...
'"'
..
:;
::J
o
Z
w
o
o
<(
o
o
o
o
o
o
o
o
o
o
o
o
o
o
-
"
::J
o
E
<(
"
"
.;:
a..
-
'"
::;)
5'
<(
0 '" N M
~ '" '" ~ "" "" M <D M
~ "" '" '" '" 0 ""
m "! ""- N CO '" M
< ~ '" N N- N
W
~ a
a..
::;;
<(
0 -
lL "" <( <( <( <( <( <( <( <( lL lL lL lL lL lL
0 ::;) W W W W W W W W --1 --1 --1 --1 --1 --1
?-
m
w
~
0
....1-<(
~c'll:t
"'<(- ~
ma; ~
o~E 0
Ow '"'
-0"
lll~m
Cl ~ ~
--1 '" " b in N '"
--1 ~ e e e :!. :!.
w ::J' ::J' ::J' ::J' ::J' ::J'
~ <( ~ <( ~ <( <(
--1 " S oc a:: oc a:: oc oc
0 0 S w w w w w w
:;::: ~ I- !;: l- I- !;: !;:
~ ~
0 0. :f..- <( <( <(
<( .;: ::;; ::;; ::;; ::;; ::;; ::;;
0 " S 0 --1 --1 --1 --1 --1 --1
.. 0
~ " ~ a <( <( <( <( <( <(
--1 0 :f..- a ::;; z z z z z Z
--1 E ::;; a a a a a a
,
w ~ U W I >= >= >= >= >= >=
~ w w W 0- 0- 0- 0- 0- 0-
-' 0- 0- 0- Q. Q. Q. Q. Q. Q.
0 >- t >- > > ::J > ::J >
s S t:. t:. --1 --1 --1 --1
::J ::J ::J ::J ::J ::J
:f..- :f..- ::;; ::;; ::;; S S S u u u u u u
a 0 0 a:: a:: a:: a:: a:: a::
<i) ~ I- 1= I- :f..- :f..- ~ w w w w w w
::i l- I- S S S S S S
2- 0 0 0 iO ~ iO
m m (]) (]) (]) e,. w w w w w w
2- ::i rn rn rn rn rn rn
a:: a:: I I I ::;; ::;; ::;; ::;; ::;; ::;;
::J ::J U U U rn rn rn
S S t: l- I- W W W a:: a:: a:: a:: a:: a::
Q. e. e. --1 --1 --1 a 0 0 a a a
rn rn a 0 0 l- I- l- I- l- I-
l- I- l- I- l- I I I rn rn rn rn rn (f)
w w w w w Z Z Z W W W W W W
--1 --1 --1 --1 --1 <( <( <( 0- 0- 0- 0- 0- 0-
Z Z ~ Z ~ ::;; ::;; ::;; 0:: 0- 0:: 0:: 0:: 0-
~ ~ ~ '" N '" '" M co 0 ~
0 '" <D N '" co ~ 0; N ~ N '? M "f ...
<D '" , , ,
z "f "f u;> u;> u;> N , N r:: ~ ~ ~ ~ ~
~ ~ ~ ~ ~ ('OJ "" "" "" "" ""
E , ,;, , ~ ~ ~
,;, ,;, ,;, ,;, ,;, '" '" , c. , c. , c.
~ N N N N N N ('OJ N 0 0 0
... ... ... M M M M M M
... ... ... ... ... ... ... ... ... ... ...
o
o
o
o
o
o
o
o
o
o
o
o
o
o
'"
...
::;;
:J
o
Z
lU
o
o
-<
-
C
"
o
E
..:
"
l.l
""
"-
-
"2
::l
C
..:
0
C<: " <'"l .... <'"l <'"l 0 N <0 " ~ .... "' <'"l
<0 <'"l N ~ ~ ~ N 0 0 ~ .... ~ ~
m 0 m m_ N "' ". m_ <'"l <'"l N ~
< ~ N ~ r-: .;
w <0
~ a
"-
::;;
..:
(.) -
LL "2 LL LL LL LL LL LL LL LL u.. u.. >- >- >- z
0 ::l -' -' -' -' -' -' -' -' -' -' (f) (f) (f) f-
?-
m
w
s:
0
"I-":
"'0'"
N..:_ 0
U;>oC: ~
en " '0
OC<:E
OW ....
-0"
llICl!m
Cl c-- ~
-' :;,. 0 N W
-' e ~ t::- u
w :::J :::J :::J ::s
s: <{ :'!; <{
-' 02 02 "-
c tl:
Q. 0 w W W W ~
:;:l !;( f- f- f-
0 Q. <{ <{ ~ 0 (f)
<{ ." :2 :2 :2 ~ ~ ~ <{
0 l.l -' -' -' S?. 5Z'
1/1 6" 6" ~
C<: " <{ <{ <{ :::J -' W
-' 0 z z z W W W LL -' ~ tl:
0 0 0 (f) (f) W ~ -'
-' E <{ o~
w >= >= >= <{ <{ f- W W
" U U ~ W 5: IU
s: "" "- "- "- "- 0
z z >- "- (f)-
-' S S S W W :::J I::. >- tl: ~ otl:
5 I::. W 5Z' 5Z' ZlD
> > > f- f- <( U 6" 02 -' <{;;:
-' -' -' 0 0 tl: Z U tl: ~ ~ <{
:::J :::J :::J 2S 2S 0 W Z <{ I I tl: >e:tl:
U U U W "- :::J
0 U ~ 0 lD f- f- Zw
tl: tl: tl: 5' 5' U w ~ ~ f- <{f-
W W W .... .... :::J tl: U lDoo!
5: 5: 5: 0 0 S!. W lD tl: f- W -u..
W W f- tl: 0 w U U !::: ~o
w w w -' f- f- tl: Z Z
(f) (f) (f) I I <( :::J :::J <{ U 0 0 I lDW
U U C> U tl: Z U U U lDC>
:2 :2 :2 ~ ~ tl: W <{ 0 tl: :::J(/J
tl: tl: tl: 0 0 f- "- U >e: >e: <{ ~W
0 0 0 U U Z Z W W -' -'
f- f- f- > > <{ <{ tl: (f) Z <{ <{ (f) ,,-0
(/J (f) (f) "- "- I lD U <{ 5: 5: tl: <{:::J
u.. 0 W tl:-'
W W W W W W tl: Z <{ W W ;;: ,,-U
"= "- "- "- "- "= :::J 0 tl: W 0 0 -Z
"- "- a:: a:: a:: "- U U f- :2 iii iii "- tl:v
N <'"l "' <'"l CD
0 "i "i "i ~ ~ 0 :;:
~ N ~ ~ .... ~ <'"l
Z ;::: ~ ~ , , , N , ~ ~ N '"
<"- <"- CD CD ~ ~ "' , N , ~
E ~ ,;, , a a ~ N , ,
m m 0 N N N CD 0
, a a ~ N N <'"l
" 0 a a N N "' en en
"" <'"l <'"l <'"l "' en en '" '" '"
<'"l <'"l
.... .... .... .... ....
0 0 0 0 0 0 0 0 0 0 0
0 0
'" 0 0
0 0
.. 0 0
:2 '" .,;
=> - CO '"
0 c: "'- "'-
z
W ::l ~ ~
0 0 <F> V>
0 E
<( <(
0
0
0
0
" 0
" .,;
.;: CO
0- co_
-
'c
::>
C
<(
0 ", I'- M M co N
a:: co
'" ... '"
'" co '" "'-
<( ~ o:i .,; co
W ~
~ a N
0-
:;;
<(
0 -
LL. 'c LL <( l'Ii LL <( <( >- <(
0 ::> --' w --' w w (/) W
I-
'"
W
;:
0
1'-1-<(
"'0'" 6'
"'<(- 0
"loC: z ~
", " z -
oa::E 0
Ow w "'
-0" a.
1lI;2'" a
0
Cl N
--' ~
c ,
--' (/)
w w - 6' ~ z
;: a:: w z ~ CJ
:s a.
--' c: t. z i2 U5
0 0 lS w W I-
'" >- >- 5' a. > z
0 Co --' --' I- a w w
<( .;: CD CD ~ 0 --' :2
"
0 Ul :2 :2 <D i= w
a:: " w w f=' z 0
--' 0 (/) (/) I S <( z
--' E (/) (/) CJ 0 6' ::J
UJ <( <( jjj i3 a --'
;: " w z w <(
'" UJ UJ I --' Z 0 0 Z I- '"
--' CJ CJ 0 CJ 0 z z 0 UJ
0 ~ ~ z 0 ~ <( I- a::
0 :::; a z ::>
~ a a ~ ~ ~ a ~ I-
::? I I a 0
;:; 0 0 ;;... ro ro LL --' i= ::> a;-
0:: --' 0
z z e <( 0 a:: M
0 a <( <( w W ::J ::J <( I- ~
<( :2 CD a. a. l- (/) 0:: 0 en ...
w 0 0 ~ ~ :2 ?- M
Z a w z z w w UJ (f) a:: 0
a g;;, g;;, w w a. 0 !::: z = 0
>- w w z >-
I- --' --' --' --' l- I- ~ <( a ~ a:: z
(/) ~ ~ ~ ~ <( >- 0
cj :2 0 "
Cl 0:: 0:: 0:: CJ CJ 0:: <( ~ 0 Cl
Z 0 0 0 0 z w w a s: Cl Cl "tl
UJ .;:
0 0:: 0:: 0:: 0:: i3 0 0 LL 0 Z UJ I- ~
0 <( <( <( <( z z Z 0:: <( ::J I- <(
W ::J ::J ::J ::J UJ W UJ UJ a a <( u "tl
CD CJ Cl CJ Cl LL LL LL a. 0:: 0 0 c:
>- E
-
0 N '" s: ", en
0 N '" co N ", Ul
~ M N N N ~ 0 ",
... , ,;, ,;, N N 0:: J, 'n;
Z I'- I'- '" '" '" ~
'" , cb co co , '" ", "
E co ~ co co '" ~
M M M cb cb , '" '" I'- '" ",
" '" '" '" M M C) '" '" u Co
'" '" '" '" '" '" E
'" '" '" 0 0
0 '"
0
~+'~_'",w._..' "~"_...".._."_
o
o
o
o
o
o
o
o
o
o
o
o
o
o
'"
'"
:.
:0
o
Z
UJ
o
o
<<
-
l:
::l
o
E
e(
'"
"
.;:
c..
-
'2
~
C
e(
0
0:: N i'- 0> <0 N "' " N 0 0 " 0 "' "'
N '" '" 0 '" '" '" <0 co 0> 0> en
'" " N N ". '" i'- '" "- N '"
:;;: ~ ~ N- O; ori ori
w ~ '" "
~ a ~
c..
::;;
e(
0 -
LL. '2 >- >- >- >- LL. m m m LL. LL. c( LL. LL. LL.
0 ~ 0 0 0 (/) 0 -' -' -' -' -' w -' -' -'
I-
'"
W
;:
0
.... l- e(
co C "
N -
.., e( l: 0
a. 0 '" ~
0 0:: E '0
C W <D
iii c '"
~'"
Cl
-' d
-'
w (/)
;: '"
-' l: ~
(5 0 c:
:c "
C a. >
e( .;: 8
0 "
<II
0:: '" oil
-' C -0 a
-' E "
w .<:: (/) '1ij ~
;: '" ~ :0 a;- :0 '" '" 0:: .(ij
"" ~ ~ .c 0::
<Il ~ " a;- '" " ~ "
-' " Uj Uj :is "
(5 ti " ti " LL. c:
ti ::l a.
2 .<:: 2 ti .<:: - Ol " 0 ~
Q 2 '" " >
1il <Il -0 1il 2 <Il " ~ 8 e.
~ 0 1il '" Q; 1il 0 a. 0::
" 5- .0 "- 5- >. Ol Ol
a. ::l Ol a. .0 t:- " oil ~ .,;
::l a. ~ c: " " " a. W Q
~ :'S c: ~ ~ :'S '" -0 '1ij .1ij
.:; ~ E t; E " 0:: 0::
2 0 .<::
OJ " e a. 0; 0; 0; <Il c: <Il '"
W W ~ 0 " " " " 0 c: 'c ]i ]i
~ ~ Q (9 " U5 U5 U5 m 0 >. ~
Q Q c: Z 0 " "3 "3
c c: 0 0 Ol Ol Ol -0 -0 u.. m lD
0 0 0 2 " "
0 0 0 c: c: c: '" '" -0 '" E E
~ u: '0; 'e "e 'e '" '" <Il ~ " "
= 0 ~ ~ 0 0:: c: c:
" a. J'? J'? J'? -'
'" '" '" Ol 1il 1il E E
'" '" '" E c: c: c: 1il ~
<Il <Il <Il -0 .iV .iV .iV " " '" " "
~ 0 " "
0 0 0 0 0:: 0:: 0:: 0: 0: l- I- ;:;' ;:;'
0
z '"
E 0 '" , N ""
" ~ "' i'- 'f u;> q> ';- , i'- "" 6 6
" N , ..J- " " "" "
"" N en ~ ~ ~ ~ '" i'- i'-
6 , , 6 , ,;, , ,;, 6 ,;, ,;, ,;, 6 6
0 0 0 "'
0 0 0 0 0 ~ ~ co co "' co <0 <0
" " " " " " " " " " " " " "
^~-'_"_"'~'__'~'__'~~_"_~'_"_~_~.__"'__"'"__"",.'_,.,__._..'._."'N____~.~,..~_" .--.,-.-.-.
o
o
o
o
o
o
o
o
o
o
o
'"
..
:E
::>
o
z
UJ
o
o
<(
-
"
::l
o
E
-0:
"
u
."
c..
-
""
:;)
C
-0:
0
0:: 0 ""' ""' <0 ~ ""' en N 0
en en en en '" '" ~ ..,. '"
Ul '" "'- '" 1'--- ""'
;,;: ~ ""' ~ 0
W <0 '"
~ a
c..
:;;
-0:
U -
u. '" u. U. LL >- Z Z LL >- ro >- ro
0 :;) --' --' --' 0 I-- I-- U) 0 --' 0 --'
I--
Ul
W
;::
0
I'-- I-- -0:
'" C ..,.
N -
"' -0: " '"
a. 0 " '0
00:: E
C w r-
iD c "
Ul ~
~ ;;a
Cl !S
--' ;;a (j)
...J !S u
w '"
;:: (j) LL
<1l
...J c. :0
" '"
Q. 0 J:: :J
'" U) 0
c c. cL 0 '0' t
-0: ." N E "
u N ~ >
0 on '" '" '" :;
0:: " C "" I..Li on 0
C <Ii "
...J '" !S L "C
...J E Ol '6 ~ ::l ><
"C 0
W ,gj 'C " Ol i.L (J ro
;:: @. ~ ~ e. ..
'iij .. t::' <Ii :J ..
...J ~ W " " I'-- .. :J 0 :J
0 " 0:: 0 " 0
"C ~ ~ " C
'C 'C " :J 0 ..,. 5 .. " "
OJ OJ (J (J .c '" t C .!ll C
ro ro >- c U) 0 u " .!ll ID .!ll
u '=- "" ci 2 > ID u ID
Ol Ol iii - ci5 :; u .. u
~ ~ c -'" Z 0 .. ~ ..
- " c ~ ~
'iij 'iij 1il E '" " Ol 2 2
0:: 0:: ro Ol c
c. " "C t=i ID 0 ID
u u '" 0 <Ii J3 .. 0 ..
:;= :;= OJ -b :0 " 'x .. " a .. "
'" '" 0.. c .0 C w .!ll ci5 ..,. '" ci5
~ ~ 0 0 0 u
c '" :J ci5 0 '0 Ol + Ol
'" U) a:: a <Ii c ~ c
" " m .~ I'-- " .~
1il 1il 'C ci ci Ol ..,. 1il ..,. 1il
u; c >
G G [!! [!! '6 + 0 ~ .E <Ii G .E
" en u
c C "C 6. 6. "C I'-- E c c ci5 c c
0 0 " " ..,. " 0 'm 0 'm
0 0 0.. oc oc ro <Ii a:: 0 a:: 1ii 0 a::
ci5 Ol
c
1ii 'q; ""'
ci ~ <0 .. <0
Z t '" , , 0 ~ ,
" , ... ~ U ..J- ~
E > 0 , , ,
~ (<) ~ (<) :; 0 ""' 2> ""'
" , J, , <0 ..,. 0 ~ 0
'" ""' <0 ~ I'-- 0 ... ..,. ..,. ...
, , , , , 2> :g
~ ~ ~ 0 0 ><
N N N (<) (<) '" 0 5:
'" '" ""' '" '" '" ro
--~---~~-,,-~_.,-,,~-"._,--_.-
0 0 0 0 0 0 0 0 0 0 0
0 0
'"' 0 ci
0 0
.. 0 0
" 0 .;;
::> - 0 0
0 c: '" M
Z ::l <I> <I>
UJ
0 0
0 E
.. <I:
0
~
0
0
" 0
" 0
." 0
c.. '"
-
'2
::>
C
<I:
0
0:: 00 N 0 00 '" '" "- '"
'" v '" '" <D
rJ) ~ '"
<( ~ ci
w '"
x: 0
c..
:;:
<I:
0 -
LL '2 (I) >- OJ (I) (I) (I) <I: <( <(
0 ::> --' 0 --' --' <( <( w w w
...
rJ)
w
;:
0
"- ... <I:
00 0 V
N -
'" <I: 0
c: ~
mO CI> -
00:: E 0
Ow '"
-0 CI>
llli:! rJ)
5'
C) <(
--' rJ) 0
--' C) a:
w z LL
;: i2 0
--' 0:: 0
Q. c: ~ <I: z
0 ;;j ;;j :;: w
'" ,
0 Co ~ ~ ... ;::- w
<I: "" z (I) [L
" i;
0 on Co Co w LL 0
a: CI> >< >< --' :;: (I) [L
--' 0 ;,- ;,- <( W N W 5'
--' E ~ ~ ... ~ ~ --' w
w 0 CJ ...
;: " "' c.. z
'" .!!l :J "' .!!l ... <( z z
--' 'c; 0 :J "c; rJ) 0 I LL @. ::>
0 :::> " 0 :::> w w z ... (I) t: 0
c: " 0 0:: <( :::;;
t .!l! c: t (I) '" W z
" a; .!l! " z ::> C) (I) N > :::> ...
> > <( ... w N (I)
""5 " a; ""5 s: 0 z 0
"' " Z 2- ~ w 0
0 ~ "' 0 0 ::> :::;; --' e:.
"0 ~ "0 0:: C) ... f- W CJ
--' ... (I) (I) ~
" :i " --' (jj z a:
"0 0 a; "0 <( U) 0 0 Ui w
'Uj 0 "' 'Uj [L [L Z ~
d> 0 "' " , (I) CJ
'" ii5 " w = - w w a: 0::
" v U " 0:: >- >- --' --' Ui 0 <(
1: + Ol 1: a: 0:: CJ CJ !;( :::;;
~ c: ::> CJ
f- "- as f- f- 0 0 ~ Z
1;) v Q; "13 1;) 0 C) C) Z W f-
(j (I) (I) i= z 0
'" <1i t; C '" :::> w w z z w
" ii5 c: " 0:: ... < (J) ::; ....,
" 0 "v " f- <I: CJ CJ X w OJ
~ n: Ui
[L Cil 0 a: (I) 0 0 (I) W 0 0
Ol
c:
"Uj 'f- N ...
0 ~ '" ~ 'f ~ ~ ~ ~
0 00 , .0,
Z .;- 0 , ~ .0,
~ ~ :3l:::> <D ,;,
~ 0 .0, ,;, ~ ... ... v ~
E ~ '0:: .0, .0, , 0 ,;,
~ 0 ;;: Of- 0 0 0 "-
'2 v 0(1) "- "- 0 0
"- "-
;;:
""'.~ _._"_,_._"...._.~ .______.__.w'___."~.___.__.."..Oh_'_._.._~__.~..,.___,_..."...__ "'" ._~_.____._.~__....' _._."_,~_~ ..",__,,_
o
o
o
o
o
o
o
o
o
o
o
o
o
o
0>
...
'"
::J
o
Z
w
o
o
<(
-
c:
"
o
E
<C
"
<.>
";:
c..
-
'"
:;)
C
<C
0 '" I'- '" 0
a:: 0 N ~ ... (J) <Xl '" <Xl I'-
... 0 CO ... ~ ~ '" I'- ... '"
CIl ... ... CO ~ N ~ 0
< r= N ... N
w
!<: C1
c..
:;;
<C
tl -
u.. '" <C LL ::;; ::;; LL LL LL ::;; LL <C <C ::;; LL
0 :;) W -' Z Z -' -' -' (9 -' W W Z -'
I-
CIl
W
s:
0
"'I-<C
~C~
"'<C- o
moa; ~
-
oa::E 0
Ow '"
-0"
lll;2C1l
Cl
..J fe-
..J
W (j)
s: W
..J c: ~ z
i5 (j) ~ ~
0 W :J fe- fe-
'" 0 w w (j)
0 c. w ::::> 0 (9
.;: -' ~ :;: 6' 6'
<C > -' -' fe- ::::> <C
0 <.> i= III W (f) 0 :J :J
'" S2 C. (9
a:: " 0 ~ ~ iL (f) a: 0 0
..J 0 W 0 ~ N 0, " ;,; w a: (f) ~
-' E -' :"i w fe- e ~ ~ !:::!. S2 ~ 5 ~ ~ :;:
W LL (f) (f)
s: ~ W III 0 W W W W W W W W W
a: W 0 0
..J Z t: t: t: t: t: l- t: t: t: -' -'
i5 0 t: 0 I I I I I I I I I -' -'
a: I z ~ ~ ~ :;: ~ ~ ~ ~ ~ w W
I- ~ :"i c. c.
w 6' 6' 6' 6' 6' 6' 6' 6' 6' 6' 6'
a: "- (f)
'=- l- I- l- I- l- I- l- I- l- I- l-
I- S2 ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~
Z I-
W (f) Z 0 0 0 0 0 0 0 0
0 0 0
::;; w <( i= i= i= i= i= i= i= i= i= i= i=
w "- "-
~ i'2 ~ (f) (f) (f) (f) (f) (f) (f) (f) (f) (f)
w :"i :"i :"i :"i :"i :"i :"i :"i :"i :"i
I- >
"- (f) i= "- "- "- "- "- "- "- "- "- "- "-
a: 0 0 0 0 0 0 0 0 0 0 0 0 0
w u:: w ::;; ::;; ::;; ::;; ::;; ::;; ::;; ::;; ::;; ::;; ::;;
Y: LL -' a: a: a: a: a: a: a: a: a: 0:: a:
a: <C LL W W W W W W W W W W w
<C a: w I I I I I I I I I I I
::;; I- a: l- I- l- I- l- I- l- I- l- I- I-
~ N ~ :;: ~ ~
0 I'- 0 co <Xl <Xl ~ co <Xl
'" , ~ ~ ~ N , '? ..,. , <b
z <b N '" I'- , ,), ,}, '? "( <Xl
6 6 '? '? '" ~ '" '?
E a '" '? '? ~ ~ ,
" I'- ~ ~ ~ ~ , ;::: ~ I'- 1- ~
~ I'- I'- ~ ~ ~ 1- ~ ;:::
I'- I'- ~ I'-
I'- I'- I'-
0 0 0
0 0
'" 0 0
.. 0 0
:;; 0 0
::J '" iii
a - ~ ~
z c: <f> ...
W "
a 0
a E
~ <I:
0
"<
0
0
" 0
u ,,;
.;: ~
0..
-
"c
=>
c
<5
0:: m
'"
en ~
< ~ N-
W
1C a
0..
:;;
<I:
0 -
u.. 'c u..
0 => --'
....
en
w
;:
0
.......<1:
~c"l:t
"'<1:- 0
~oi ~
oO::E 15
OwO> 0
-0" ~
lll~en --'
<I:
<.'l ....
-' 0
--' ....
w w en
;: 0 <.'l
-' z z
c: ~ ~ S1
~ 0 10 0::
:;:l :s
0 C- o <I:
.;: 6' --' :;;
<I: --'
0 u :J <C ....
III
0:: '" 0 Cf) z
--' 0 ~ <.'l w
--' E ~ z :;;
w ;;z w
;: ~ 0 a:: ~
-' --' <C 0..
i5 --' :;;
w oll
C. .... <.'l
6' z
w :i!:
.... :;; z
~ w <.'l
0 ::c Cij
i= [L I
Cf) 0
:) -
z ~
[L <C
0 <.9 0
:;; z <.'l
a:: z w
w <.9 ~
:r:
.... (j) 0
~ :;;
ci 00 [L
~ Cf)
z , 0
E '"
'" '"
~ , m
~
~ 0
... 0
MEMORANDUM
To: Kevin Dugan
Project Manager
Collier County TECM
From: Scott Bear
Project Manager
CH2M HILL
Date: November 4, 2009
RE: Oil Well Road
Segments 2 & 4A
Collier County Project No. 60044 & 60044A
In response to questions/comments received from Collier County Traffic Operations and
Interested Bidders after the submittal of the Bid Plans on 9/16/09, we have prepared an
addendum to the plans package (Addendum No.2). A package of the addendum will be
submitted under separate cover lelter. The following is a summary of the sheets modified
and a description of the modifications per sheet:
Project Component Sheet
Segment Set No(s) Pescrip.tion
2 Roadwav 1 Added revisions
15 Added Summary of Guardrail Removal
table
30 , Modified Concrete Quantitv
40 Modified Concrete Quantitv
41 Modified Notes 29 and 35
120 Added Note
120A New Sheet.
Added Concrete slab details for
Structures S-137 and S-144.
120B New Sheet.
Added Pipe Grate Details for S-137 and
S-144.
122-136 Modified earthwork quantities
143 MOdified earthwork quantities
171-182 Modified earthwork quantities
183-189 Modified earthwork quantities.
Updated pond cross sections and
stations.
199E Added Limits of Construction to cross
_~~ection
199G Modified earthwork Quantities
. 203 Modified Note 7 Phase I, Stage IA
218 Relocated construction zone
288 New sheet to show typical section on 33fO
Street Access Road
289 New sheet to show cross sections on 33'0
Street Access Road
Signing and S-3, S-4 Modified Pay Item numbers.
Pavement Modified quantities.
Markino
S-5, S-6, S-8, S-14, Added 6" Yellow Skip (2'-4') to left turn
S-21, S-22 lanes at signalized intersections
Signalization T-1 Modified Sheet numbers.
Added Revisions.
T-2 Deleted Pay Item Notes (moved to sheet
2A).
Deleted notes 14 and 28.
Modified notes 5, 19,23,25,26,27,30
and 32.
Added new note 32.
T-2A New sheet.
Modified and added pay item notes.
T-3, T-4 Updated quantities.
. Modified pay item number (663-74-11 to
663-74-14).
Added pay item numbers (632-6-1, 663-
74-15, 678-1-105, 678-1-107).
Deleted pay item numbers (650-51-511,
650-54-311,650-54-511,659-118,686-
101, and 686-104).
T-5 Modified Signal Operating Plan.
Modified Signal Head Details.
Added Sianal Head Detail.
T-6, T-7, T-8 Updated Signal Operating Plan.
Modified Signal Head Details.
Added Signal Head Detail.
Added Sign.
Modified General Note 7,
Updated quantities.
Modified Sign Details.
Updated pay item numbers.
T-9 Modified Sign Details.
Updated quantities.
Updated pay item numbers.
T-10, T-11 Added note for Quantities
T-11A New sheet for Palmetto Ridge High
School Zone
T-12, T-13 Modified mast arm sign dimensions and
lavouts
T-14 Modified signal head assembly location
dimensions
T-15 Modified standard mast arm assemblies
to special mast arm assemblies
. T-16 Added special mast arm assemblies.
Modified data in tables.
T-18 Added quantities, pay items, and notes
for cantilever overhead mounted school
zone flashinQ beacons
T-23 Added roadway cross section (previously
omitted)
T-23A, T-23B New cross section sheets for cantilever
overhead mounted school zone sians
T-26 Added cantilever sign structures.
Modified data in tables.
4A Roadwav 1 Added revisions
10 Added detail for gravity wall/temporary
barrier wall to typical section for Sta
633+74 to 8ta 634+86
21 Added Summary of Guardrail Removal
table
35 Modified Note 34
45 Modified Riprap callouts to include
Beddinil
48 Modified Riprap callout to include
Bedding.
Deleted duplicate Riprap callout.
63-64 Modified driveway and curb to temporary
barrier wall and qravitv wall
96 Added begin and end bridge stations.
Added earthwork Quantities.
97 Modified earthwork quantities
110-112 Modified earthwork quantities
116 Modified Summary of Earthwork
quantities
Signing and 8-3. 8-4 Modified Pay Item.
Pavement Modified quantities.
MarkinQ
8-16 Modified striping at driveway access (Sta
634+001
Computation Table of Contents Modified page numbers for 520-1-10.
Book AddedJ2.8qe 240.
147-148 Updated quantities
149-176 Deleted
240 Added new pav item
In addition, the quantity items identified above have been modified in the Bid Worksheet and
the Engineer's Opinion of Cost.
If you should have any questions or additions/deletions or corrections to the above Summary,
please do not hesitate to contact me.
cc: File (331629/A1)
~Go~
. ._.~ ~~.._,-:,,---
~SelvicEsDivfs1on
Purd1ilStrig
Attendance'Sheet
/yoN- Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening -c Segments 2 & 4A"
P LEA S E P R I N);,.., .
Name: .4JfH..-;U~ / j~1i '> Name: :;;.CO~ ge/WZ
Company: i)t_H01r--~/c: Fttkt1'5i Company: O;l2M. I/iU....
Address: L./ ~ c:.) ;4-"",f'-Itl<' ~ Address: Z,Z-<:;"' G. ..e,B/MS"'N 2>-;r:-
G't.. yfi( tt~ ).,i /,.~ CS;;O~
City: J7..,~D:!),K:s. \Ill "-F City: r{JR-bANtJD
State: rL Zip: State: Pi- Zip: 3,z,Bol
Telephone: Telephone: 4iJ'7 <' 423 .. 00 .-g 0
, "
FAX: FAX: 4>7- 83'"j-s"'7n I
Email: MLJr...:JA-fU{:.~ e f>>ytA,-E/1:. JU.slEmail: 5:becu--@ c124- <?:n"1.
************************************************************
Name:
If-II,~ I?~ II
&lJ.r ~..ds
Name: .JOE f2e<OTINO
Company: BeTl~12- Bop.os
Address: 1'110 S/iiiWI;......{l..J)
Company:
Address: 19/.1) Y<.Vcu-r:/ /!ve,uf-,
City: vI~tI Ie 5
State: r( Zip: :3 (/tJ'l
Telephone: (Z~1) 511- '2-/15/
FAX: (u.1) 517-/517
Email: /0 b./"epG ,b-t/k- roJs ,,IJ~f
,
S!>>': ~
-~
~__tate:
I
Telephone:
Zip:
FAX:
Email: J;z.~.f/€J7g.i1iz..tJ~5. ha~r
G/AcqulstionsfTechFormsandLetterslMandatoryPre-BidSigninSheet
Bevised: 3/20/09
o~Jt O{-~ s.Lelv ~
. ftL.;I" ~ I?(~~b S'\-
(-~It.-k ~ IOl4l lL C
3 g,~ 1't tiltH' ')0 01. .v 2.1!-
lU.qfl~~ F{ 5't{II~
~.3ct. ~ J It. .t- 2.00
~. ~11J ~,HOf::..
C=>" 4" i' ~JI ~
34~ fJtrL.712O rt<oJ 'I
. Pr.M y(',,~S
,"-0)23"-334 -3&5Z.
CF) 70'1-33"3-o'!- '{O
l!.JiJI~ ~ ~"'t..~-;>",,\h~~ . M "1
.
ba6('W"l-4 Ge..4IC.,LsLvk cr-
. Ale. ,
~o~e iZT CJM /IJd//v(J
Cr"lte.r4Jlec.o l..lc.
d8't '-( M iJI'Vi11( 1(' 0", t./ ..I/..
IV l'l~le~ f( 34ft {If
rO~I!I'L\
otCtlJ"d'N~ l~
-e-' " tM. 4' L . Co-i.1
..1 '
,., ,
AtJot(etJ t-/ I r, If
AfL.Df(f'\A:1,,1 f 4'.J;'oc.
9970 BAVI'I!Z..,II] t<D.
r-otZ"I /1""E::;-<, s, (" '- 3"S 913
CrJq-'L A 11\4H e. }fJ..OI11'1r{"J. <-0""
fr/ 2?? 7b?J {,6oo
Ct< z3<7 76c;{ 6'-101
Co.qo~y
'~_.--;"'--~
AdrrinisIJalive SeIvires CMslon
Pull:lT.ising
Attendance Sheet
NON- Mandatory Pre-B'id Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening - Segments 2 & 4A"
.--:--- /J/ / PLEASE PRINT
Name: /0 fY] f<.-hA CleJ" Name:. J) 61< F C/c. 1'"'\ oo,eLb I?
company:,l?}wd0 /'J/Id:J ~cI".f' Company: .D . rJ. WI ?c./rV".!., S:r-v!-'
Address:~~/Otl J!D/V''jiJ- G~ O/C Address: If'Cfh- :r;",,-1-f'rW"/T"~' A~_,
p
, (\(--1 t../ / tL J1-tr P (I
City: r-~ "f!-e J I Pi- 3'f I P'1
t='['
City: 4A/-Tf(J- s;?e,.v6...f
State: ;L'/c>;(.LJ'7IJ- Zip: 31-/3S'
Telephone: .2. 3 q- LJ-D~ - e 16&
FAX: .1--3 q- 1-6 s-- tiJ /6 7
Email: ~ @.. ,.eM rI6 A-/!I() l!M(l5 ,,/\r~f
State:
Zip:
:5<-; I '0'1
Telephone:.2J '1 ~ -n 'f '--- '3/3 <J
FAX: ,;L;> q r
77'-(,- 4-2-t t
Email: d........O<l~j!cJd..(".J...Ii...\.co...-....
City:~Lo
Zip: 1<//09 State:_tG iiP:~
Telephone: 39~-~'IS<) Telephonl 1.'>J~? / Ll,9;h
FAX: FAX: t~... ~ ~ / ?G()6
Email: HI1JTJ!rJr:lDf?- ffi~,.@ 0JI.!-tERCoJ .;.e-7Email: -C. \(J li01\ e- C\ C\ SvQjOl1"~c,,.COrl)
Name: %;-J!/ C/J.{j}O/, "
I
rl?/lr)('/lJ;fr/J now j}~.
Address: hP';;' / J.,'/)//J6.fttJdtJLIS )Ai
NnM1Gr
City: ;J Iff}, /:'J'
Name:
~"'" .
..
o{dCfYl
, ,,,,,,.,-,
************************************************************
., .;., ..,' ..
Company:
Company:
(j
/~I
Address:
State:
F;.
~
G/AcquistionsrrechFormsandLetterslMandatoryPre-BidSigninSheet
l3.evised: 3/20/09
J;
OVUZ ~
JoHN fJ5'c.HClt I
5,r. WCOTEN CofZP.
/0560 M 4'5$' C I,
Ff, MYE. R. 5 PL ~ 3'1( Z
J
2.~'1-337- 1'-1'3& PH-,
Z ~ "i - "33 7 - '1'1'6 '6 FAX
John,P1 7CJ,eU iCE, 5f-W corp- com
a~(~ ;JIU/<YL-Sud
~e 1-14f2 ~/L-7)IA..J(.r<f-~J<>"';
/~b8S- jJptC Bow: B. .
F: j//t/~2S; ~ 5'~66
/&,EF:' Z~9 - t.{81- Uf::t
~ "L~~ - ili3(-'9'S'~4
t'IIRt::L..N1 Ct/'-JL 5'D~(!. tI1Je1f.fU 4c.~4I
i
/ I
~OfJ <:of;,-...It>-- L-1\o"L,2-r r/u{,.ft.S..5 i
f'm-,,- ~I..-i=- CO-'t.-p.
q&}oc> C~~O P"f>..l::: Lo",~o~3. \~c...uo.:ft-I
r;;s (;;5,4.- c> (FL 3f7 2:;
flol:M.<"2. C3-)7) 2,."2-'1-,s,"-b8 (
PAr- C2~0 qq{) -~19-~1
-s LDFF",~e 12-,fl,,(Ot-r=-.Lu___
L ISY(2.JVFS- e. (l.yV\....~ot-i=.CO....
I.- r-tu(.~5 e.. (>-Y"'-~o'-I::-. (.".....
0&00'. ,...~
_. _ ~..' . . "~~IUJ
....,~~~_._,.,.-.:~,-
Adninislr.llive Se!vicils Division
Purd1~in~
Attendance Sheet
/YON - Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening.,.. Segments 2 & 4A"
A PLEASE PRIN{:--. I
Name: o-,ON '1)~() Gk-. Name: ~ ~--eh!
Company: ~yY'cl..'C\'C'\ Con-St-.-. Company: ~~ Ca-o,'''t- ,
~ ,&
7)",.?, g~ Address: :<:D"> SV-J S 'i&'\--
3o~
.~
Address:
Email: oa'O"<'">, "a~ Y"V\O\"IY'^ ~,fP.,-th \~n 't,M}Email:
City: ~~ (' oreJ. ~
State: -0 Zip: '33~i{
Te[ePhone:\~9) 57>-t- ~I('-f
FAX: Cd-oeD 57'1- LtClGt I
~d_~'^""1~~e~"''''''~ ,~--f
City: /::"'~ C-D<"'e>...Q
State: -+=l Zip: 33<=1~ I
TelePhoneC~ S7tf - 2..\- 174
FAX: ~3~) S(;.f- -'to 9 I
************************************************************
Name:
{;? lOf lJcrU
/l-IJ~
Name: ~ U/.... /(Avt:;
Company: t! i3 ,$,M/-1tJlV 125 fL.-J;c.
Address: t,://)" ti>r!..IJ/2tL5 r::;::-,yl 1/';::>
. .
Company:
Address:
/ /-:; w. (~d"';v,d A/A/r /?~
tr//.u/-<<' ~~d~,.,) ~
City: ,///~l/'~L.,<.: (;7
City:
State: PL- Zip: 3<11/1
Telephone: ';39 -,)';1- #-',"Z-s---
FAX:
State: ~~ Zip:
Telephone': If ~;!~. 7. 771)
FAX:
Email: C h/.?/s. C/bYL'c. <8A/.J5-jOl;oe.c<-'1 Email: iMil.".)I?/~..5>HIIP.1./25.fJ-c/
. v
G/AcquistionsfTechFormsandLetterslMandatoryPre-BidSigninSheet
l3evised: 3/20/09
c&.Co~
-.- ... '''_'''~'..~.~r~<... -',.' d,_ __~
AdrrinistJalNe 8EirIiires DMsion
Purd1<i,sing
Date: October 26, 2009
Attendance Sheet
NOAl-Mandatory Pre-Bid Meeting
Vendor Sign-in
BID # 09-5287
"Oil Well Road Widening -,- Segments 2 & 4A"
:D (j, P LEA S E P R I N'D
Name: PnJ I b /}1 A.u Name: '",\, I '" 'Ml>..(7..T' f ,.j
Company: cJ.1JUJa?;/tL G'f~~1 Sc(~V",I7.> Company: Ii \ \JV\ EtJ(""tVf.l'.Jz..rNG-'~ Su !:.JE;::i'r-:()-/ (N:.
Address: $7/ ~"'(j- LtL~ J>z. Address: S3:>D L.L (?[.-I/V~
City: fi I?1F
State: ht,/2f tJA Zip: -=139o.S
Telephone: 239-'195:-/997
FAX: 23'7-"'.?/3- 2347
Email: d{).vYIA-foJel1l1i.Je~h--Wjf~.(t7tt{
City: w-" '7 h (jaz..€.,;> ~
State: F L Zip: 'S 3'7 '7 /
Telephone: 2-'5'1. 4:,72- - 000 0
FAX: "2-39 - 332- q, 731-
\ f' n' I .
Email: C\.\Mc..v.~o-.\\Y.t-...1)...af.I~.c.o w"---
************************************************************
Name: ~ b Thol'1\ f.:lCf'/
,
Company: Ph,,'..,S , ~cdll'" :r;,~
I
Address: yo lSo,< z.,t...qS
City: 7.~hr(' h, (I?
State: FI-
Zip: '33'S" 3 <t
Telephone: 8f?'- 7B.-S-/(gz,.
FAX: 8 f,~' 78 ~ <s/<l6
Email: -ffe5t.t ,...,~( ~ po.l'O ~. e.O/YI
Name: C~* lec,;t
Company: W \) K \ ~ L
Address: <6l'L) ~~'-l~-+(\\' \ Q~'-~
~~
City: G~"-,,,,~ ~\.'\l c...
State: ~ , Zip: '+~ ~ J
Telephone': ~l ~ \00 lp -1J-tOO
FAX: G \0 \oO~ -llt\ )
Email: W~~~--L<l.-.~YGL.co~
GfAcquistionsrrechFormsandLetters/MandatoryPre-BidSigninSheet
F3evised: 3120/09
Col&~
--"--,-~-'---:-::,..~-
AdnirislIalive Services DMs10n
Purch~inti
Attendance Sheet
/VO~- Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening -:- Segments 2 & 4A"
~ PLEASE PRINT .
Name: -':."tfF"~" ,<<.." Name: V()HIJ j0fH..f)flFlf
Company: 1")u;:2A=\ ElL. Y'~:- -;&11' .5. Company: tv I L- '?ON Ivt I L-L8Z-. INC-
.
Address: 2-1 gc; 4-'1t;Lj c.<W. Ft.-yf;/2... ~ Address: ~ UX) 8ftlLI?) LN S(JfJ"E Z::<::5
.3,Zon ~5lJ'uS. r:-<.-- 3'1(,0'1 Ntr
State:
Zip:
City: NIrf?U?5
State: If-
Zip: 3tjJOS:-
-Z '3'1 - (pi.fq - Lf-o YO
z '?9 - 2
City:
Telephone: ~Z.-7'" --:S:QAf'1
FAX: ~z.- 79 (, -~'}33
Email: ..j ,:)Al,/1S.~0",,'t.q,~,-.JI{~-
Telephone:
FAX: 1=,
'-'
Email: jOhlltl-.lA!oae71!J. WI /~N)/YI1 Iter. LO~
Name:
Dw,J sJ:~i:;'**"""""""""~::~:"*[;;::;:;'~iilikr
fkfJCos1- (.Jail ~s){""'.r Company: UJ.I~" In/{~r fve-
/'i?9Y' Nt() :Jrf-Jc/ Address: 3'2eJd &~~ f..e...... e.-
4pl~1<-O ~
Company:
Address:
City: U~
State: pI-- Zip: 3CfIfJ5-
TelephonJ 1111 237 647 L(Ot.{O
City:
State:,/l: Zip: ~o6' f'
Telephone: 7"Pi- 1?3- Yf"lTf"
FAX: 9f~- 7/.7- 777:2...
Email: d<!J.("Jl@j7~~cJ(.Jd!s.c(J7Yl
FAX:
La nee ;J?/k/"(? wi 50'1 /l.t- ,;;-{o fYl
Email:
GfAcquistionsfTechFormsandLettersfMandatoryPre-BidSigninSheet
l3evised: 3/20/09
Co.Co~
'-..~::.-.-:_--
Adrrinlslr.lli\ Seiviiis Division
Pu~$iF1il
Attendance Sheet
NON_ Mandatory Pre-Sid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening..,. Segments 2 & 4A"
Name: ~T~lL -r:; Frv
Company: 't-II-Aft ('0"'61 iLvr-'1/0N
PLEASE PRINT
Name: t/.4Dt?AJ lJ. lit/a
Company: 4Et:. r9c4't:/?AL :rue.
Address: <F'~ (e /:' pc) 801( /:?fI;;
Address: 3":iOC;;- ~...Mr j?"p,.<:l
L.
City: N A?\h
State: f(...
City: / IF /'/J";,4 Ar:-R,!'L;
Zip: 3<(!I'J ~
State: U
Zip: :3 3'f7()
Telephone: 1,,4; - ~oo-v
FAX:
1<:>43. 2611.{
Email: pe./~r-ft!!..klz.4F"f(.I1..vS 7/J.vt ~/'" N". <'.. '"'1 Ernail:
I
,TA-l?oll/ Jlt/Ll_ j;) ./Jf41&,,yGI? <''''11/
************************************************************
Name:
/6","1'-- Kee.- Name: :::::r Q, '"" -eS CO f~ I~
?I';f,"-'<.. ~tr=*i~ Company: --=r'h D tvlfsoV) P" '"' yO
{Oto ~(...!......... .#\"110'--- jJl'";>-;.Je, /loAddress: ,')491 \)1-115,'.),,", \)r'
-r:.....J.l4, F1.. '517 .
. I
r:;;-....p"-
Company:
Address:
State: PL- Zip: 33' ( "
Telephone: ~()7 -7v,;L -1$60%
FAX: if/:?-t"l1-S'f6/
State:
City: _F'L My"'-..- 5
~I Zip: 339r;!5
;).3 "7-7-!j1--(; (;;)5
:;;l ~ '7 - G,'1.JS- (j9,/J Y
0,c<:>(dc.l't d. @ f~_!5G>n .j7p""jJ,co#"'{
City:
,
Telephone:
FAX:
Email:
a;k:ee"l@ Pr-t'nre .-sJ,., c."""
V. I
Email:
G/AcquistionsfTechFormsandLet1ers/MandatoryPre-BidSigninSheet
l3evised: 3/20/09
Co~~
. ' "- !'I-,----:..:-.:_.........
Adrrinislralive ServfOOs Division
i'Qrch~$ing
Attendance Sheet
NO^l- Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening..,. Segments 2 & 4A"
Telephone:
2.. 5 )-
Zip: 635'/ <
b <:'c?- .::?/6 t:
PLEASE PRINT ,...'r~" 54. 1/12flO
Name: f12.40.....,'Cc...u '-tT,..1"--
Company: pe4bP-j)OS us.4
Address: 2 4WA-U.f>12{}. PLI/-Z!l-
5<J/T1l:- (,,60
City: coi24L G.A-BLES
FL Zip: 3"3 13lf
Telephone: 90S- - L{2. 3. 7600
90s;- - l42-~ 760(
Name: A-L.-/7-N fJP-"V;'"J
Company: (/ '-' t... Q.,/f-.J dt~r 6,;3 frLr
Address: ('" '/-.? yt( ;f 0 ~o /.... c:L
City: h- .dt), ~~r
State: ",C{ <
State:
FAX:
FAX:
Email: ntLlr/;"rA- <L Vvt.\.c-""'A-c~. ~...... Email: FSf>!A-2I}e~PI~A-(..IU;O.s-VSA.~
************************************************************
Name:
:;;_'7 ~ .a~
Name: J<.8J'-A ~~I'rnf
Company: ~0fV10Yi /V!rrriJ\R _ WI15-fIVc--h01
Address: (Jqqq tI/4L GlIol"I C..~
U
Company: ? FP Q-v ftv<'/m , ..:;t:"
Address: 7h?- (;;;;."" f/w/.'
City: ,.A;a~4
State: ./Z Zip: J}j?/;7
Telephone: ;;219" ;;;"/7 /f"7::r
FAX: ;;l.:J7 (l./?- ;7jr/;1
City: ~r-l- fl-.. '-/ <?J\--
(
State: H Zip: 33f1~
TelephonJ: 2..3"J 33')- aoof?
FAX: 3:) 1 Omf7J
Email: kc...sHlf.0 reM, W~
Email: Z~Ci....e>.tf~/..c>1.....
, .
G/Acquis!ionsfTechFormsandLettersl1v1andatoryPre-BidSigninSheet
f3.evised: 3/20/09
cokemmt
:,~.~~:.: ::,,:_~~:
Adrrinislralive Services DMslOI1
Pu~ii'ij
Date: October 26, 2009
BID # 09-5287
Attendance Sheet
No N - Mandatory Pre-Bid Meeting
Vendor Sign-in
"Oil Well Road Widening - Segments 2 & 4A"
Name: 13; () Ana"" J}p 'r
Company: 0.. 'Pr1l ~
Address:/ 9 J 99' A-I/Qd '?cJ I
I
PLEASE PRIN~ lJ
Name: --..J ~ 'w".d
Company: (i-C/'1 c;;;,;~~;:..
Address: (G(;J-I he ~ fP//O
City: ,t::-y A Y~Y-:=' {
+-- f
state: F 1. ~ Zip:, ~ -5'9/3
Telephone: ;J.:3 g ~ '71;6 ~
FAX:
Email: ---.kh..!}/c\..Mo. /1 c'l U D'; fY a pqc '<:!l ""-
/ .
City: if fi/v&14
State: ~ zip:5"3f/2
Telephone: 7:""]'1-:>:J0 'lgtJD
FAX: '~9'- '5"J9"- nD (]
Email: j d..utytY1 e :Y:V""1onf;ac:fnJ' ?Oi?-?
************************************************************
o
Name: r/~/ll 1'1 #' CI /IJ jV A,
Company: G e'IV l? C (J;tJ /1Y. A (;/7 tV G
10,t?'jV/ tJL../Tlo~ /11/
?O~rL;1o/JrlJ/Jlj:-'
Address:
City:
State: F L Zip: 333/d--.
.
Telephone: 9' ~ 5-" - 6~ft';J... 37'::; (,
FAX: f15~~-5'll -tiSlI(
Email:
Name: -K"e; j \:?'eru.....
Company: ."Ja\c..~-r CO ,:).s\fl-0C-'TI~ &:QoU~
Address: !;:S \ \ 'fou ..K...Q..0 \ ~\ lLo.
./
City: r-,... - M 'I e-.e-3
State: 0,-- - Zip: -s.:SC( l?--.
Telephone: 731 -48 I . S-=
FAX: ;1..~'T-48\ -~
Email: c.;:::.:~...i3<>:.w.L-\6.\-lT6.C C>"""-
G/AcquistionsfT echFormsandLetters/MandatoryPre-BidSigninSheet
Revised: 3/20/09
dfAtr-~~J
_..- .~" . '~~~J
"~'~"'-'
AdIrinislralive SelviOes Divislon
Pur<::hasing
Attendance Sheet
NON- Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening -,.. Segments 2 & 4A"
Name:f5j2,.;o ~f'o61/-~S'O
Company: ~.?' yo' el< IE .
/
Address: ;3'85'0 -r.Lt!tr "".:V.r
PLEASE PRIN,~ .:h.
Name: w....r .-
L.o~-ZA'(")
"""I
$.
Company: At.e... l---....e,...""l-r-I.....c.
Address: f>. O. f$....-.l 1"18(p
City: ~ #;yo,ts City: J...e.h~" Pre-res..
State: -ri ' Zip: State: ~L Zip: ~~9~o .
Telephone: zg"l '11"1- 9.$ ~.5 Telephone:. (~:S'\) 4/'1. 10:1."''1
FAX: FAX: (~3."') .:<.'S~- 018~
Email: &:.... e,h"I>4"SCO(2e.iy(l""~,IA71>>; .Wf Email: h \ ~,,'Z~o lii:l ""':""...~. C-!:>""
K~' tv! D" ("~t*.****.*.*..**.~******.*********************************
Name: ~,,41' 1~fu/~j.; f1..1)u--eh fJ/~ Name: I4 v : d. c;j(...E!.-'e.-Y\iQ..
co~ Company: ~5lJSIS,.J W&.-4:'e-ltJ...,~_~
Address: Address:
City: pj .ftf t/
State: r; Zip:
Telephone: l,3/j. 707- tf336 ,
.7,31 . 3JJ. . 3G/Y
City:
NlLpJe- S
~ l .
FAX:
Emai1: k.Jt)PtJr~(!'{r(t{tL6f1 .{tn1"\
FAX:.
G/AcquistionsfTechFormsandLetters/MandatoryPre-BidSigninSheet
f3.evised: 3/20/09
Co.~
--............... ..
AdminislI<dive ServfcesDiviSi6n~
PU[cl,a~ing
-,
Attendance Sheet
NdN~ Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287
"Oil Well Road Widening -,- Segments 2 & 4A"
FAX:
Emai/j-Rremf. (//6-08 e ,tLi,NdCd/Y'
PLEASE PRINT
Name: v'~LJ H,.,t,z/7I<J
::.~::=z;:~:~.
/7li +-7 R- 33.?~,5
City: .FJ;,~w---)
State: F L- Zip: ...s37b'~
Telephone:2~,.~ ":'::;:-:-:;;:..3
FAX: o?:'?5f .~<;/ /J? ~/<;/
Email: bl fiJI~,.,6 ~4' %.#",-g1(H*r~. ~
Name: :S'ff-emfa&/I
Company: //,;.AhHd t;1I5"lr!)d~
Address: 1tJ5'" 4/;:::;/tt1/ bur'! ,I'd
:5/1.;/1)
City: -7,;,1>-,)
/
State: ;:z. Zip: 3J(P/~
Telephone: J!5 ~ @(fS - ~15
************************************************************
, 'JZ'~ "2 Ae.AaV'6--
C. DNC//"< ~ j:'/1t;tll'es,5 td v<;
7 II :5 t.. s-fl:.'J4-u-(.
7"'.
City: (0 OLp J p_ '> City: _pl7Y"f/tl1{) T3~
State: r J.. Zip: :5 lj) c) '7 State: --.:;.-f Zip: 3"3 tJ t. tJ
Telephone: Z3t}- ~ '7 7 ~ Z}t.,S Telephone~ 3"\ 3- 371r 'j''lZ1
FAX: ?-'3Q- Sl.-C" -78~ FAX: "011- fl7q~ /10.)
Email: e f e.,..v"'-'e,j P~Jv/.l-.J-cA ell s-lG.'-k Email: ::YO f. @ C. r. ::J/ortdo<""l ~
. ~o "I
Name:
~I' It... --J Pti;!..-v~e'J,r Name:
M 7.,)-u e if rI-- ~ 1-....,. h. 4n1slc c~ompany:
~ .J2../Lr
i.co l S h \J' le-y ..t.r Address:
Company:
Address:
G/AcquistionsfTech FormsandLetterslMandatoryPre--BidSigninSheet
~e\{ised; 3/20/09
c&~
. ,--~:'-'--.~-
Adrrinistralive SeiviOOs DMsioil
Purtfr.j"ing
Attendance Sheet
/VON- Mandatory Pre-Bid Meeting
Vendor Sign-in
Date: October 26, 2009
BID # 09-5287 "Oil Well Road Widening.,. Segments 2 & 4A"
~~ I A _ P LEA S E P R I N T/7/ /J
Name: I ~ VII/I T Name: L/f'/lf t~iJSS
Company: . I TL-K f?pCl)!. / Company: Ibln/~. tI,vsIn..c.L CII?/-l.
Address: .;2 ( ? O.;f7YKO~ClUtHOv[J~ Address: fJI!N f~}.o,$(2 fof.. .<J~ 3dD -
(f)/Vcoksv;//€!,' f-bvl(;tc<--Jc(~ ~
City: City: f)~
State: ,iF- I - ziP9-(604 State: F (
Telephone: if en-hi. r;-22Zl--
FAX: J r;2-'19~r ~9~~ .
Emailf)1lavll@dL{;yO~k..ne)
Zip: 3"33:2- t(
'i'pl' ift?3- fJ?(P{"
Telephone:. ~
FAX: 1''14' '1.73 - 6ft) ~
Email: (.C(JO$.>(AJ;A-f./pkJ.;.aw-slru.c.l-~ . ~
******************************************.*****************
Name:
Name:
Company:
Company:
Address:
Address:
City: City:
State: Zip: State: Zip:
Telephone: I
Telephone:
FAX: FAX:
Email: Email:
G/AcquistionsfTechFormsandLetters/MandatoryPre-BidSigninSheet
l3evlsed: 3/20109
~~...
,". --_.-~,'--. ,'--
AdrriniStialive ~ DMsion
f\Jrt:hi:\$ing.
Attendance Sheet
IVtJtJ - Mandatory Pre-Bid Meeting
Collier County Department Sign-in
Date: October 26, 2009
"Oil Well Road Widening - Segments 2 & 4A"
BID # 09-5287
G/Acquistionsrr echFormsandLetters/MandatoryPre-BidSigninSheet
Revised: 3/20/09
Cottr County
-. ~.... -
AdrrinistJative Services Division
Purchasing
Email: BrendaBrilhart@collierQov.net
Telephone: (239) 252-8446
FAX: (239) 252-6697
ADDENDUM
Memorandum
Date: November 12,2009
From:~ Brenda Brilhart, Purchasing Agent
To: \.:.. Interested Bidders
Subject: Addendum #4 - ITB # 09-5287 - Oil Well Road Widening - Segments 2 and 4A
The following clarifications are issued as Addendum #4 identifying the following change for the
referenced bid:
. Subcontractors do not need to be FOOT qualified:
Florida Law (Chapter 337.14 F.S.) And Rules of the State of Florida, Department of Transportation,
Chapter 14-22, require contractors to be prequalified with the Department in order to bid for the
performance of road, bridge, or public transportation construction contracts greater than
$250,000.00. Prequalification is not required for the following:
1. To bid as a prime contractor on projects of $250,000 or less
2. To bid as a subcontractor in any amount
3. To bid on buildings (A general contractor's license is required for this type of project)
4. To bid on maintenance contracts
. Revised Bid Schedule
. Revised Plan Sheets - Signalization
. Exhibit J-12 of the Technical Specifications entitled "Right of Way Considerations" is
deleted. All Right of Way for the project is now available to the Contractor.
. Exhibit J-8 of the Technical Specifications entitled "Fill Dirt Agreement" states the agreed
price of $2.45 per cubic yard. This price does not include Sales Tax. The Contractor will
need to include the payment of sales tax on this material when preparing the bid. This is
also a cubic yard measure of loose material in the hauling conveyance at the point of
delivery and not compacted material in the roadway embankment. The Contractor will need
to take into consider shrink when preparing the bid.
. The awarded contractor is responsible for paying the sales tax for fill material. It is not
included in the stated price.
. Technical specifications for proposed Closed Circuit Television equipment used by the
Traffic Operations Traffic Management Center are attached.
. Communications Interface and Fiber Optic Modem: As of June 2007, fiber optic
modems are no longer used for traffic management communication. The standard is a
gigabit Ethernet switch. Technical specifications are attached.
If you require additional information please post a question on the eBid site or contact me (contact
information above).
c: Gary Putaansuu, Project Manager
Enc: Bid Schedule
Plan Sheets - Signalization
Spec Sheets - CCTV/Switch (combined in one file)
2
C)
C)
C)
C)
C)
C)
C)
C)
C)
C)
C)
C)
C)
;t
::i
::>
o
z
w
o
o
..
~
c:
::l
o
E
<(
Gl
U
";:
c..
~
'"
~
c
<(
0
n:: N ~ 0 (0 (0
~ CJ) '" ~ ~
Ul ~ '" ~
:;;: ~ ~
w U)
~ 0
c..
:;;
<(
0 ~ <( 0
u. '" (f) (f) (f) (f) (f) 0 u. u. u. ~ >- >-
0 -' -' -' -' -' - -' -' -' 0 0
~ (f) (f)
I- -' -'
Ul
w
:=:
0
....1- <(
~O ....
~
U)<( c: '"
a.O Gl ~
on:: E '0
Ow ..
-0
m~ Ul
Cl
-' I-
-' :)
w a
:=: 5
-' c:
~ 0 0
""
0 0. Z (f) W
<( I-
<( .;: Z -'
0 u C9 :)
III (f) W
n:: Gl z Z :;;; 0
-' 0 ::i >= :) w
-' E w Z I 0
W "- > a 0 z
:=: .. lY (f) lY
'" :;;; a
;:... :) I- a w lY
-' =o! (f) >- 0 rr -
0 :) w w 0 w w C9
~ al Z > -, li: ;;;j lY lY "- Z
a lY 0 u. u. <( lY ~ lY
(f) i= :) lY <( n: al <( w ::i
0 ~ 0 (f) "- lY >- al al
<( :) I- :;;; I- W :) :)
z u. Z w 15 ~ 0 0:: Cl
a :;;: lY a ~ u. I- Z (') W
n:: I- a m
I- (f) Z 0 0 W lY
Z Z Z a z w -' lY m LL 0 I-
>- a :;;: a i= :;;: 0 ~ :) lY ~ Z Z z
n:: ~ :;;; 0 :; :;;; Z I- :) <{ a w
0 W W <{ C9 I- (f) (') i= :;;;
w Z lY Z Z ~
Cl 0 0 lY 0 W W 0 0 ~
w ::i :> :> w :> I- i= w w rr z
I- al (f) Z lY <{ ~ ~ <{ <{
<( a a a w a :;;: lY a ~ <{ w 0 al
0 lY lY lY lY <{ -' I- -' X :;;;
:;;; c.. c.. c.. c.. :;;; al LL (f) (f) 0 w w
0 ~ 'i' '? ~ ~ N ~ ~
z ~ , 'i' ~ .... ~ ~ M , ~ (0
, ~ ~ ~ co:, ~ , 0
0 , , , 0 , .,J- .,J- ~ 0
E ~ ~ ~ 0 N , , N N
0 0 0 0 0 0 ... 0
~ ~ 0
o
o
o
o
o
o
o
o
o
o
o
o
o
o
:;!
:2'
:0
o
Z
w
o
o
'"
-
"
:l
o
E
<l:
.,
"
.;:
a.
'"
"
::J
C
<l:
0
n:: U) ..... 0> 0> ..... 0 "" 0> "" U) "" N ~ ...
M "" ..... ..... "" CD M "" U) ~ ..... ~ U)
m "" ... CD CD ..... ..... M CD .....- ~
;;: ~ .-: oi " <<i u? c:i <<i c:i 0 M
W ~ N N 0 N ~ M
~ a ~ N N N N
a.
:;
<l:
0 -
LL '2 LL >- >- >- >- >- >- >- >- >- >- >- <( <(
0 ::J U) U) U) U) U) U) U) U) U) U) 0 0 w W
?-
m
w
:i:
0
"I- <l:
l:lo ..
-
It)<l: " 0
';'0 ., ~ ;:" ~
~
on:: E ~ ~ :::J 0
Ow '" ~ N
-0" N N --'
lll[2m N N ~
J, J,
Cl ..... ..... j:::
--' ;:" (9 (9
--' ~ ~ ~ ~
w
:i: 5' 0 5' 0::
(9
--' " 0 0 ~ 0::
0 0 U) u: u: LL N 0
., W LL LL LL N
0 Q. n. <( <( <( J, !!::.
<l: .;: 0 0:: 0:: 0:: ..... (jJ
0 " --' i:::- i:::- i:::- (9 --'
'"
n:: ., U) w w w ~ --'
0 --' ;;:- 0 <(
--' ~ l- I- I- iD S
..J E 0 0 ~ w w w
w ., U) n. n. n. 0:: 0:: 0:: 0 (jJ (9
:i: .. 0 ::> ::> ::> 0 0 0 !!::. --' z
0 0 0 z z z --'
--' w iO ~ z
0 0 0:: 0:: 0:: 0 0 0 ;;:
0:: (9 (9 (9 0 0 0 N 0 I- 0 0
0 w w w 0 0 0 0 I- Z W
LL lD U) U) U) >= >= >= z !g ~ ::!.- ::!.-
z w <( <( <( --' --' --' !!::. w
w n. Ee. Ee. Ee. <( <( <( w :;: w w iO iD
0:: j::: I I I W l- I- , rb.
n. n. n. U) > w w ~
--' --' --' 0::
0 <( <( <( U) U) U) <( 0:: 0::
>= Z <( <( <( ::> n. 0 0 m m
0 z z z 0
w 0 0 0 w w w I z Z 0:: 0::
I >= >= >= >= ;;: > > 0 0 0 ::> ::>
I- ~ <( <( Z n. 0 0 ~ ~
z n. n. n. n. n. n. 0 U)
>- ;:j 0 0 0 0:: 0:: 0:: >= <( U) U) U) U)
U) iii w w w w w w t.i U) U) l- I-
0 ~ U) U) U) n. n. n. 0 ~ :"i :"i w w
w <( <( <( ::> ::> ::> C2 --' --'
(9 U) lD lD lD U) U) U) LL :;: 0 0 ~ ~
0 ... M ... 0 ~ ~ ~
... 0 ~ N U) CD
~ ... 0 ~ ~ ~ N N N ~ , ~ '?
z ,;, 6 ..... ..... ..... , , , ~ d, ~ , '?
~ ~ ~ ~
E , ,;, ,;, ... ... ... , 6 , ~ ~
... CD U) ..... M 0 , ,;,
~ co "" co M M M M M 0 0 U)
N N N M M M M ... ... N N
... ...
o
o
o
o
o
o
o
o
o
o
o
o
o
o
;j;
:;;
:::>
o
z
ill
o
o
<i
...
c:
::l
o
E
<(
0>
"
';:
0..
""
c:
::J
C
<(
0 '" '" en ~ ""'
0:: N ""' r-- r-- (0 ""'
~ r-- '" en '" 0 r--
rn "! r--. N "" '" ""'
:;;: ~ '" ~ N N N
W
II: 0
0..
:ii
<(
0 ...
LL '" <( <( <( <( <( <( <( <( LL LL LL LL LL LL
0 ::J W W W W W W W W -' -' -' -' -' -'
f-
rn
w
:i:
0
"'f-<(
~c'll:t
Lt)<C't: 0
~Ocu ~
-
OO::E 0
ew '"'
-eO>
lIl<(rn
0::
Cl ""' ~ ~
..J Co ;,- b (0 N Co
..J ~ ~ 8 8 :":. :":.
w :J' :J' :J' :J' :J' :J'
:i: <( <( <( <( <( <(
..J c: 6" 0:: 0:: 0:: 0:: 0:: 0::
5 0 6" ~ w w w w w w
:;:l ~ 6- f- f- f- f- f- f-
e a. :f.- <( <( <( <( <( <(
<( ";: :;; :;; :;; :;; :;; :;;
0 " 6" 0 -' -' -' -' -' -'
0:: on ~ 0 a <( <( <( <( <( <(
0>
..J 0 :f.- a :;; z z z z z z
-' E :;; a a a a a a
,
w 0 W I i= i= i= i= i= i=
:i: ~ w w w n. n. n. n. n. n.
..J n. n. n. Q. Q. Q. Q. Q. Q.
5 6" 6" ~ ~ E. ~ ~ ~ ~ ~ ~
::J ::J :::> :::> :::> :::>
:f.- :f.- :;; :;; :;; 6" 6" 6" 0 0 0 0 0 0
a a a 0:: 0:: n:: n:: n:: n::
G' 9' f- ~ f- :f.- :f.- 6- w w w w w w
, f- f- S S S S S S
:::;. :::;. a a a 00- O? O?
co co 1Il m m , w w w w w w
eo :::;. :::;. (f) (f) (f) (f) (f) (f)
n:: n:: I I I :;; :;; :;; :;; :;; :;;
:::> :::> 0 0 0 (f) (f) (f)
s S f- f- to w w w n:: n:: n:: n:: n:: n::
e. e. e. -' -' -' a a a a a a
(f) (f) a a a f- f- f- f- f- f-
f- f- f- f- f- I I I (f) (f) (f) (f) (f) (f)
w w w w w z z z w w w w w w
-' -' -' -' -' <( <( <( n. n. n. n. n. n.
~ z z z ~ :;; :;; :;; n. n. n. n. n. n.
~ <0 en N '" en ""' "" 0 ~
0 '" N '" "" ~ ~ N '" '" '7 '7 'i 'i
(0 en en
Z 'i .,,- 'f 'f 'f , ~ ~ ~ ~ ~ ~ ~
, N r-- r-- r-- r-- r-- r--
E ~ ~ ~ ~ .;, .;, .;, ~
, .;, .;, .;, ,
0> '" '" N N N a a a a a a
"" N N N N N .,,- .,,- .,,- ""' ""' ""' ""' ""' ""'
.,,- .,,- .,,- .,,- .,,- .,,- .,,- .,,- .,,- .,,- .,,-
o
o
o
o
o
C>
o
o
o
o
o
C>
o
o
it
'"
:J
o
Z
ill
o
o
<<
-
"
"
o
E
..;
'"
"
";:
c..
-
'"
::l
6'
..;
0
0:: r-- <'") ... <'") <'") 0 '" r-- ~ ... '" <'") ...
'" <'") N ~ ~ ~ 0 0 ~ ... ~ ~ 0
'" 0 '" "'- N r--_ '" <'") <'") N ~ ...
<( ~ N- M
w
II:: 0
c..
:;;
..;
0 -
u. '" u. u. u. u. u. u. u. u. u. u. >- >- >- z
0 ::l --' --' --' --' --' --' --' --' --' --' en en en f-
f-
'"
w
3:
0
r--f-";
~C"lt
"''';- 0
mO; ~
oO::E '0
Ow V
-0'"
lD..;'"
0::
Cl ~ ~ ~
--' ..- b N W
--' e ~ t:- O
w :::J :::J :::J :5
3: ..; ..; ..;
--' il: il: il: 0-
Q. " z
0 W W W W
., ~ f- f- f-
0 Co <{ <{ ~ 0
.;: :;; :;; ::;; ~ e. ~ en
..; ..;
0 " --' --' --' S Q'
'" 6' 6' ~
0:: '" <{ <{ <{ :::J --' W
--' 0 z z z W w W LL --' ~ 0::
0 0 0 en en W ~ --'
--' E <{ ..; <{ o~
w ;:: ;:: ;:: f- W $: W
'" 0 0 ~ 0- W IO
3: "" 0- 0- 0- Z Z >- 0- 0 en-
--' Q. Q. Q. w w :::J C t- o:: ~ 00::
0 W Q' Q' zm
> :::; :::; f- f- ;;: 0 6' 0:: --' <{It
--' 0 0 0:: Z 0 0:: '" 0 <{
::J ::J ::J ~ ~ w 0:: "0::
0 0 0 w 0 0- Z <{ I I ::J
0 0 ~ 0 m f- f- Zw
0:: 0:: 0:: 6' 6' 0 W ~ e. f- <{f-
W W W ... ... ::J 0:: 0 m~
$: $: $: 0 0 ~ w m 0:: f- W ~u.
W W f- 0:: 0 W 0 0 !:: ':'10
W W w --' f- f- 0:: Z Z
en en en I I ;;: ::J ::J <{ 0 0 0 I mw
0 0 (') 0 0:: Z 0 m(')
:;; :;; ::;; ~ ~ 0:: 0 0 0::
0:: 0:: 0:: 0 0 W <{ 0 " " <{ ::Jen
f- 0- 0 f'Sw
0 0 0 0 0 Z Z W W --' --'
f- f- f- > > <{ <{ 0:: en Z ~ ~ en 0-0
en en en 0- 0- I m 0 :::: 0:: <{::J
u. W 0::--'
W W W W W w 0:: Z <{ 0 w w ;;: 0-0
0- 0- 0- 0- 0- 0- ::J 0 0:: W 0 0 -Z
ii: ii: ii: ii: 0- 0- 0 0 f- :2 Ui Ui 0- 0::"",
('oJ <'") '" <'") '"
.; ... 'f 'f ~ ~ 0 ~
, ':' N ~ ~ ... ':' <'")
z ~ ~ ~ , , N ~ N ,
<0 ~ , ,;, , N N <'")
r-- r-- r-- '" ,;, ~ 6 ~ <D 6
E ~ ~ ~ '" '" 6 6 ('oJ N N
'" 6 6 6 6 , ~ N N N on '" '" N <'")
"" ""' ""' <'") 0 '" '" '" '" '" '"
... ... ... <'") ""'
... ...
0 0 0 0 0 a a a a a a 0
a 0
0 0
it a 0
a 0
2 .,; .n-
O> ~ co co
0 l: "" ""
z = ~
w 0 '" '"
0
0 E
<< <
a
C)
C)
0
" 0
" .,;
';: co
a. ""
~
'"
::J
6"
<
0 en r-- '" '" <D ("oj
0<: <D
'" ... '"
oo co '" en_
;;: ~ ai '" co
w ("oj
~ CJ
a.
::;;
<
0 ~
LL '" LL < <l: LL <l: <l: >- <l:
0 ::J --' W W --' W W (f) W
I-
oo
w
3:
0
....1-<
coO'" 6'
N<~ 0
'901: Z ~
-
g~~ Z 0
Ow '" w '"
a..
-0" 0
lDi200 0
C'l N
...J 6"
--' ~ (f)
w w 6' 0 z
3: 0:: W Z ~ l'J
::5 a..
--' l: ~ Z (? U5
Q. 0 is w W I-
., >- >- 0' a.. > Z
0 Co --' --' I- 0 W W
< .;: ro ro ~ 0 --' :2
"
0 III :2 :2 ;::- oj i= w
0<: " w w Z 0
--' 0 (f) (f) I ~ <l: Z
--' E (f) en Q 0 6' ::J
W <l: <l: C3 0 --'
3: " w W Z W <
"" W W I Z 0 Z I- oo
l'J l'J --' is z
--' 0 l'J is z 0 w
0 <l: <l: Z 0 ~ <l: I- 0<:
0:: 0:: C) :J 0 Z ::J
s:- O 0 ~ ~ ~ ~ 0 ~ I-
:::J I I , 0 (,)
<l: ;g; 0 0 ~ m- m- LL --' i= ::J a;-
S 0:: --' 0
Z z e <l: 0 0<: M
0 0 <l: <l: w W ::J ::J < I- ~
<l: :2 ro a.. a.. I- (f) 0:: 0 oo ...
w 0 0 >- ~ :2 ?- M
Z 0 W Z Z W C w (f) 0<: 0
~ es 0 w =
0 W w a.. !:: z 0
>- W W Z ~
I- --' ~ --' --' l- I- I- <l: 0 >- Z
(f) ;:;: ;:;: ;:;: ;:;: <l: <l: >- 0
:2 0<: 0 "
l'J 0:: 0:: 0:: 0:: l'J l'J l'J 0:: <l: i:: 0 C'l '"
z 0 0 0 0 Z W W 0 S C'l "0
W .;:
is 0:: 0:: 0:: 0:: 0 0 0 LL 0 Z W I- ~
0 <l: <l: <l: <l: Z Z Z 0:: <l: ::J ~ <
W ::J ::J ::J ::J W W W W 0 0 (,) "0
ro C'l l'J l'J l'J LL LL LL a.. 0:: 0 (,) l:
~ E
~
a ("oj '" en '"
("oj '" co ~ ("oj en III
0 ... ~ '" ("oj ("oj ("oj ("oj ("oj ')' 0 en 0;;;
Z r-- , ~ , .;, 2> 2> , ~ 0:: ,
~ '" en
, ID ID co co 0 .;, 2> m "
E C) , , ~ co co m ~
'" M '" co co 2> 2> 2> r-- '"
" '" '" '" '" '" '" m 0 Co
"" '" '" '" '" '" E
'" '" '" 0 0
0 '"
(,)
o
o
o
o
o
o
o
o
o
o
o
o
o
o
;j;
:;;
::>
o
z
w
o
o
<<
~
"
::l
o
E
<(
Cl)
0
.;:
0..
~
'"
::>
C
<(
0 N '" ..,. N 0 0 ..,. 0 '" '"
D:: N I'- (J) CO
N '" 0) 0 '" '" '" CO 0) (J) (J) (J)
'" ..,. N N ..,.- '" I'- 0) ..,.- N '"
;;: ~ N cri ,,; ,,;
w ~ '" ..,.
~ 0 ~
0..
:;;
<(
0 ~
u. '" >- >- >- >- u. m m m u. u. <( u. u. u.
0 ::> u u u (f) u -' -' -' -' -' w -' -' -'
I--
m
w
;:
0
I'- I-- <(
co 0 ..,.
'" ~
'" <( 0
" ~
a, 0 Cl) '0
0 D:: E
Ow <0
-0 Cl)
lDi2 '"
C)
-'
-' a
w (f)
;: 00
-' " ~
0 0 "
'" "
0 "- >
<( .;: ';::
0 0 0
Ul
D:: Cl) "" ~
-' 0 '0 a
-' "
w E .<: (f) 'iij ~
;: Cl) ~ :a- m :a- '" 00 0:: 'iij
"" ~ ~ '1' 0::
'" :; ~ '" ~ ~ "
-' :J Uj Uj ::l :0 "
0 tl :J tl u. "
tl :J ~ ::l a.
.E .<: :J tl .<: " 0
0 :J '" ~ 0 '" > ~
l" '" ~ '0 1;; .E '" " ~ .;:: e.
e 1;; '" :u e c. 0
" .c a. '" >- a. '" '"
"- "- :J '" C. .c c. !::. " "" ~ ~
::l C. !!2. " " :J :J C. ~ 0
!!2. :5 'S; " !!2. !!2. :5 '" E '0 'iij 'iij
" E " 0:: 0::
2 0 5- 0 .<:
2 " 0 (jj (jj (jj '" " '" '"
~ 1ii ~ <9 0 " " Q) Q) 0 " '1' ]! ]!
>-
~ 0 Q) ii5 ii5 ii5 m u ~ "5 "5
0 0 " z 0 :J
" " 0 0 '0 '0 U. m m
0 0 2 '" '" '" " Q)
u u u 0 " " " '" '" '0 '" E E
2 u: .;;; .~ "e "e '" '" '" ~ :J :J
= = 0 ~ ~ 0 ii: " "
Q) c. 0 0 0 -'
'" '" '" '" - - - 1;; 1;; 'E E
'" '" '" E " " " - 1;;
'" '" '" '0 '$ '$ '$ Q) Q) '" :J :J
~ 0 Q) Q)
C3 C3 C3 U 0:: 0:: 0:: a: a: I-- I-- ;;: ;;:
.;
z '"
E 0 I'- '" I'- J, N <'")
..,. ~ '" 'i "? '1' ~ ... , c.
Q) N N , ..,. , '" ..,. 0
"" ..,. (J) ~ ~ ~ ~ ~ '" ~ ~ I'- I'-
C. C. C. C. C. J, J, J, c. J, J, J, , c.
0
0 0 0 0 0 ~ ~ ~ '" '" '" '" co co
..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,.
o
o
o
o
o
o
o
o
o
o
o
:;j;
:2'
::>
o
z
w
o
o
<<
~
"
::l
o
E
<(
'"
"
.;:
a.
~
'i:
:J
6'
<(
0
0:: 0 U") U") <D ~ U") (J) N 0
(J) (J) (J) (J) 00 <') t::_ ... <')
1Il <') ~ "! <') U")
:;;: ~ U") ~ ci
W <D <')
:<: a
a.
:;;
<(
0 ~
LL 'i: LL u. U. >- Z Z u. >- III >- III
0 :J ...J ...J ...J 0 l- I- (f) 0 ...J 0 ...J
I-
1Il
W
3:
0
... I- <(
co C ...
N ~
on <( " 0
, ~
'" 0 '" -
0 0:: E 0
c w ....
iii c '" ~
<(1Il ;;Ij
0:: !oS
Cl ~
...J ;;Ij a;-
...J !oS u
w ro
3: a;- u.
"- '"
...J " ro :0
0 0 .<: ::l
"" (f) 0
, 0
C Q. U. t
<( .;: N Q)
" N >
0 Ul <') <') - S
0:: '" ai C 06 0
-' C ro !oS x
...J E Cl '6 0
W "0 Q) Cl III
3: '" ." e. ~ '"
.. ~ f2 ui ::l '"
...J ~ ~ 'n; ..... Ul ::J 0 ::J
Q) Q) a:: 0 Q) 0
0 ." ." ~ ~ Q) <: Q)
ro ro Q) ... ::J '" <: .!!1 <:
'0 <') t
III III >- 0 13 Q) .!!1 a; .!!1
u 0 2 > a; u a;
Cl Cl iii U5 s u .!'.! u
.~ E z 0 '" :;;; '"
- ~ ~
'n; 'n; 1il Q) Cl 2':- ;i
a:: a:: Cl "
"- "0 ti a; 0 a;
u u ~ ." '" 0 '"
il' il' Q) ~ 'x '" Q) '" Q)
ro <: W ro U5 0 ro U5
ro ro 0- ...
~ ~ 0 0 - U + U
<: U5 0 0 Cl Cl
<: ~ <:
Q) Q) ro 0 rn ai 'e ..... Q) "e
1il ~ E ci ri: Cl ... 1il ... ~
<: >
t; '" ~ ~ '6 + 0 t; .E .E
u Q) (J) ro u
<: <: "0 , , "0 ..... E <: <: U5 <: <:
0 0 Q) "- "- Q) ... Q) 0 'm 0 'm
0 0 0- n: n: III ro a:: 0 a:: ro 0 cr:
U5 Cl
<:
ro 'in U")
ci ~ '9 '" '9
t <') 0 ~
z Q) cO .J- ~ 0 , ~
-" , , ... ,
E ~ <') ~ <') 0 U") cO U")
Q) , , <\> <0 ... ::J 0 ~ ~ 0 ~
.. '? '? ~ ..... 0 ... ... '2 ... ...
N N ~ cO cO cO X
N <') <') <') 0 5:
U") U") U") U") U") U") III
0 0 0 0 0 0 0 0 0 0 0
0 0
0 c:i
;j; 0 0
o. 0
::; 0 0
::l ~ 0 0
0 c: '" '"
Z ::l ." ."
W 0
0
0 E
<( -0:
0
0
0
0
eI> 0
" ci
.;: 0
a. '"
~
'i:
::>
C
-0:
0 co 0 CO '" '" '"
0:: N r---
'" ~ '" '" ID
rn '"
<( ~ ci
w '"
II:: a
a.
::;;
-0:
0 ~
LL 'i: (/) >- []) (/) (/) (/) <( <( <(
0 ::> --' 0 --' --' <( <( w w w
...
rn
w
5:
0
r---... -0:
~O ..
"'-0: ~ 0
c: ~
';'0 eI> -
00:: E 0
Ow Ol '"
-oel>
[])~rn 0-
C) <(
--' rn 0
--' C) 0::
w Z LL
5: S2 a
--' 0:: 0
~ c: ~ -0: z
0 Oil Oil ::;; w
:;:l ,
0 Q. !S !S ... f=" w
-0: ';: z (/) "-
" E-
o .. 00 00 w LL a
0:: eI> X X --' ::;; (/) "-
--' 0 " " -0: w N W 0-
--' E ~ ~ ... > --' w
w 0 -0: (9 ...
5: ~ 2 on 2 ... a. z z
:J on <( Z
--' "c 0 :J "c rn 0 I LL ~ :::J
5 :::J eI> 0 :::J W W Z ... (/) ... a
<:: " 0 0:: -0: :;;;
1:: !'1 <:: 1:: en '" W Z
eI> c;; !'1 " z ::> C) en N > :::J ...
> > <( ... ,
:; " c;; :; s 0 z W N a en
on C ~ w a
0 ~ " () ::> Z ~ :;;; --'
on a ~
~ 0:: C) ... ... w (9
"0 ;i "0 --' ... en en e;
" " --' iii z 0::
"0 0 c;; "0 <( rn a 0 w
'<ii 0 on "<ii "- "- z en >::
"' on " "' en (9
0 III ii5 w = - w W 0:: 0::
" .. (3 " 0:: >- >- --' --' U5 0 <(
E + Ol ~ (9 (9
.c: :::J 0:: 0:: ~ :;;;
... ;::: oi <:: ... ... 0 0 z z (9
1;) ~ ., '2 1;) () C) C) U5 U5 z w ...
oE f= z 0
III III t> III :::J W W Z Z W
" ii5 <:: <:: " 0:: ... ... en ::J --,
" 0 "w ~ ... -0: -0: (9 (9 X w [])
0: iil () 0:: "- en 0 0 U5 U5 w 0 a
Ol
<::
'<ii '... ~ ..
0 ~ on X ~ N
e ~ "i' 00 , , ~
z .;. x 0 0 J, ~ 0
~ :5i:::J ,
E ~ 0 , ,;, x ~ ~ .. '" ~
0 '0:: 0 0 0 0 ,;,
~ ~ 0 ~ x 0... 0 0 r---
~ ~ X o(/) 0 0
'!2 r--- r--- r--- r---
~
o
o
o
o
o
o
o
o
o
o
o
o
o
o
;j;
:;;
::>
o
z
w
o
o
<(
~
c:
::J
o
E
<
CIl
"
.;:
0-
""
c:
::>
0
<
0 0 r-- N ~ " '" '" 00 '" 0 00 r--
er "'
" 0 to " N '" r-- " '"
t/l "- " to '" 0
:;;: ~ N "'" oJ
w
I<: 0
0-
::;;
<
0 ~
lL 'i: < lL :;; :;; lL lL lL :;; lL <( <( :;; lL
0 ::> w -' z z -' -' -' l'J -' w w z -'
I-
t/l
w
~
0
....1-<
~C~
"'<~ '"
c>>O; -
oerE '0
Ow Cl '"
-OCll
lD~t/l
Cl
-' ~
...J
W Ui
~ W
...J c: S z
0 :J Ui ~ ~
0 w ~ ~
:;:l 0 w w Ui
0 Q. W ::> -' ~ 0 l'J S 0 0
<( .;: > -' -' ~ ::> <(
0 " i= m w (f) 0 :J :J
I/) '" C. l'J
er CIl 0 0:- (f) 0:: 0 0
...J 0 W 0 W ~ ~ N '" ;,- S" ~ w 0:: ~ ~
...J -' :"i ~ ~ ~ ~ ~ ~ ~ ~
w E lL (f) (f) ~ ~
~ ~ w m 0 W W W W W W W W W
er W 0 0
z e l- e e e e e e e -' -'
...J 0 e I
0 0 I I I I I I I I -' -'
cr I Z S S S S S S S S S w W
l- S :"i c. c.
w 6' 6' 6' 6' 6' 6' 6' 6' 6' 6' 6'
cr 0- (f)
'=- l- I- l- I- l- I- l- I- l- I- l-
I- S" ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~
z (f) I-
W Z 0 0 0 0 0 0 0 0 0 0 0
:;; w <( i= i= i= i= i= i= i= i= i= i= i=
D-
W 0: D- (f) (f) (f) (f) (f) (f) (f) (f) (f) (f) (f)
;:c w :"i :"i :"i :"i :"i :"i :"i <( :"i :"i :"i
I- > -'
D- (f) i= D- D- D- D- D- D- D- D- D- D- D-
cr 0 0 0 0 0 0 0 0 0 0 0 0 0
w u:: w :;; :;; :;; :;; :;; :;; :;; :;; :;; :;; :;;
>C lL -' cr cr cr cr cr cr cr cr cr cr 0::
cr <( lL W W W W W W W W W W W
<( 0:: W I I I I I I I I I I I
:;; I- cr l- I- l- I- l- I- l- I- l- I- I-
~ ~ N ;;; ~ ~ ~
0 "
r-- 0 to 00 ~ ~ N ~ to 00
'" , , , '7 " J:, cD
z cD N '" r-- r-- , , , '" "' ,
0 0 '7 '7 "' "' "' , , ~ ~ '7 '"
E '7 '7 '7 ~
0 ~ ~ ~ ~ ~ ,
CIl r-- r:: ~ ~ ~ ~ ~ ~ r-- ~ ~
r-- ~ r-- r-- ~ ~
"" ~ ~ ~
r-- r-- r-- r-- r-- r--
0 0 0
C! 0
it 0 ci
0 0
'" C! 0
::J "' .,;
0 ~ ~ ~
Z l: ." ."
W "
0 0
0 E
<< -0:
0
0
ci
0
" 0
0 '"
.;:
C-
'"
l:
::J
C
..:
0
a: 0'>
rJ) CD
C( ~ N
w
Il: 0
C-
:;;
..:
0 ~
LL '" LL
0 ::J ...J
...
rJ)
W
;:::
0
.........:
~C"'=t
"''':~ 0
a,O; ~
oa:E '0
ew'" ;:>
-e"
1ll..:rJ) ...J
a: ..:
Cl ...
...J 0
...J ...
W W rJ)
;::: 0 Cl
...J Z Z
0 l: ro ~ 52
0 a:
:;:l ~
e Q. ~ 0 -0:
..: .;: C ...J :;;
...J
0 0 ::J <( ...
IJ)
a: " 0 UJ Z
...J e ~ (9 W
...J E S z :;;
w 52 w
;::: ~ 0 0:: ~
...J ...J <( C-
O ...J :2'
w O/l
C. ... Cl
z
6' w z
... :2' Z
~ w Cl
0 ;:;: Cii
f= c- I
UJ 0
::i -
z 1';:
c.. <(
0 (9 0
:2' z Cl
0:: Z w
w (9 !t
I
... UJ 0
~ :2'
0 00 c..
~ UJ
z <b 6
E '7 "'
~ ~ 0'>
~ 0
.... 0
ajnpaLps P!S :::>U:J
JaBeueJIIJ pa[OJd 'nnsueejnd AJe8 :::>
'(aAoqe UO!jewJoJU! pejUo::>) ew pejUo::> eseejd uOlleWJoJu! leUO!jlPpe eJlnbeJ noli JI
'::11 OJ eJnseew JO j!un e4j peJJo::> pue BU!UOljejS e4j peJJo::> 'swejl
lied lenp e4j ejeu!wlle OJ peSIAeJ uaeq se4 qe.l P!S e4.l 'uM04s GD 36Jmut:)nb jJo,\lrlG ,8 , ~Z 63!AOJ
OSD61d '1iIOjt:)rlboPD II JOAOO II!"' wn3 dwn1 'G30GOJd IDlllwqn3 dOlj3 ljBrlOJ4j POIGOloS oq II!II. GlrlU
BU!l." put:) 3Bu!jooJ 04lJO UO!SUOWIP IDrljQt:) 04j oouIs 9 ~ !HI> PUD 9~ I> 001> 04j o,\owo~ :~3MSNV
<'-::11 eq Sl4j PlnoljS 'Sl 88 ~ SMOljS Sj!Un jJeAln8 pep!s
-eeJ4.ljse::>eJd XX-XX)( e4j JOJ eJnseeJIIJ JO jlUn e4.l '8 '(eopd Plq wns dwnl e4j uI pepnpuI eq
lIe4s swejl lejuep!ou! Je4jO lie pue suoljepunoJ eljjje4j eje::>lpu! 88 'lI ~8 jee4S ueld uo sejou e4.l)
'slleMBu!M pue sBUljOOJ lIeMBu!M 'slleMpu:J 'sBu!IOOJ dl8 eljj JOJ S! juewaoJoJuletj 'lI ou08 ::>slJIIJ
e4j J! IiJpep eseeld 'Z 'peJJOO sl jee4speeJds le::>xe e4j JI IiJpep eseeld . ~ 88 ~ Sl (1'lI::I) e8 x ,17Z)
Sj!Un jJeAln8 papIs-eeJlj.llseoaJd XX-XX)( 089'08 Sl snoauelle::>s!JIIJ 'laejS BupJoJu!atj 9-~-9~17
;::17~ A8 snoeuelleos!JIIJ 'AI ssel8 'ajaJoU08 9~-v-0017 ....OO.017HL17 'elS Ie BUISSOJ8 eJ!lPI!M awes
e4j JOJ Swajl lied lenp se4 jee4SpeeJds laoxe e4.l "swal! P!q 17# juawBas e4j JO::l :NOI.lS3nO
'GU 989'9L S! limuenb leoljJeA :~3MSNV "-':J'd eppol::l e
liq padwejs uBIsep palees 'lI uB!s e ap!AoJd OJ paJlnbaJ aJe SJopeJjUOO e41 J! IiJpep eseald oSle noli
ue8 au adolS JO ;::U aoeJ limuenb well lied ;::U 988'H ~ e41 sl 'seJnpnJjs ase4j M04s lilleowoads
je4j sl!ejap ueld ou aJe aJa4j esne::>eq sl Sl4j 'eoeJ edolS JO ;::U 91717'8 ~ ~ OJ SjJeAUOO 40!4M
'eoeJ pepe[oJd IilleoljJeA e4j JO ;::U 9;::Z'08 4j!M dn ewoo OJ elqe IiIUO eJe eM 'sedolS I!OS pe::>JoJuletj
Olje4lUlisoe8 ~-917~ #wejl lied JOJ euop ueeq eAe4 le41 s,ijo ellel uo pese8 :NOI.lS3nO
':JdOH ;:: '18 BUlpnpul
elqeldeo::>e eJe SUOljdo ed!d peAoJdde .100::1 Je410 e4.l 'pe[oJd "IiIUO d8H, ue JOU sl sl4.l .
'pejeJodJoOUI
selepdn ese41 4jlM elnpe40s Plq 17# wnpueppv llwqns liew noli - enlS - JOloO lueJe,ijIP
e uI pezlse4dwe eJe lie41 - 9# wnpueppv uI seBue40 elOU eseejd - elnpe4::>S P!8 peslAetj .
:P!q peoueJeJeJ
e4j JOJ eBue4::> BU!MOIIOJ e41 BUlIiJIIUep! 9# wnpueppv se penssl eJe suo!leo!J!Jep BU!MOIIOJ e4.l
vt> pue Z Sluaw6as - 6u!uap!M peo~ lIaM I!O - L8;::9-60 # 8.11 - 9# wnpueppv
sJepPl8 pelseJeju I
lueBV Bu!seljOJnd 'jJe41!J8 epueJ8
600;:: '8~ JeqwaAoN
:J:>afqns
:0.1
:WOJ::I
:aJea
wnpUeJOW9W
wnaN3aav
L699-;::9;:: (68;::) :XV::l
917178-;::9;:: (68;::) :eu04dele.l
leu'AObJe!l10:><!2)jJe4IPsepueJ8 :l!ew:J
6u!SB4"-JtlQ
UO\S!^!(J=JAAlS~
--.. . -~
,c:JUH.OO.1/ACPD
~ f ~ ~ ~ ~ i;'
~ ~ ~ 0 ~ ~
m N N N N '? ! 0 0 s: s: s: s: 0 3
0 0 0 0 '? ! ! , , ~
1> m &, 1> .. 5: N ~ ~ ~ , Z
~ ~ W N , ~
~ N ~ ?
(fl m m m m 0 I (fl (fl -n -U -U -U -U ;;:
:;! ;;: x x X r :;! :;! r ;;J ;;J ;;J ;;J 0 0
'" 0 0 0 ~ ~ 0 m 0 0 ~ ~
'" )> )> )> ~ ^ ^ < (fl :; <
;= Z ~ ;; ~ m m ::! 6 m 6 r m
~ ^ z 0 0 z ;;J 0 ~ G)
-< GO m ~ m m 0
;;: GO Q? -< ~ ~
-< m (5 (5 (5 )> r c -< 0 (5 ;;J
(5 z z z z -< ;;J c 0 )> -<
-< z ~ Z (5 z Z z
z 0 -n ;;J
0 (fl ;;J m 0 ~ ~ z (fl ~
-< GO -< ;;J
-< I C m Z :;) 0 0 ;;J 0
-U )> '" GO ;;J 0 :;) z -n c z )>
m z (fl c c m '" -U (fl 0 ~ 0
z Q ~ '"
'" m ~ :;) )> if; ;;J C -< (fl ::;:
r r ;;J ;;J 0 ;;J (5 ~
z -U ~ ;;J L < Z '"
GO m m ~ m m c
= ;;J 0 -< (fl ;=
-=' m -< ;;: C -j
;;J (fl ;;J
0 0 < -U
I Z m ~
c ~
m ;;: z
0 z
c m GO (fl
r Z )> i;'
m -< 3
(fl z
0 0
~ CD
~
-< Q
0 -;;'
c ~
-< o' g
:J
::;:
~
;;J
0
CD
c.
3"
3 en 00
o ~ 6
"- ~3O
cr; -CD'"
CD :I In
CD~",
;;J",CO
!'- ...
~
0
m
<
..
~
cc
or
c.
CD
(fl 0 0 0 0 !I: r r r r r r r c: !!!.
-< -< -< -< -< -n -n -n (fl (fl (fl en :J
..
~ ~ 0
N ~
<0 N 0 '"
m '" 0 ~ ~ :". ~ N
'" m 0 ~ '" ~ m
CD <0 0 CD 0 CD
c:
:J
..
"'0
~
1;"
CD
... ,.
0 0
[ 0
"'
z
0
C
YO YO YO YO YO YO YO YO YO YO YO YO YO YO "
0 0 0 0 0 0 0 0 0 0 0 0 0 0 "
Co Co Co Co Co Co 0 0 Co Co Co Co 0 Co ~
0 0 0 0 0 0 0 0 0 0 0 0 0 0
~
"
"
=>
o
z
w
o
o
'"
u;
a>
'C
..
a,
~
a>
>
ILl
g
~N~
~c:CI.l
, a> a>
~E:=
Q Cl 0
- a> E
aJ"'g
'C
..
o
t<
a;
;:
o
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
<F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F>
J9
0
f-
a>
"
;t
-
'"
:;)
()) .,- <0 00 '" '" .... N '" ......~ .... .,- '" '" '" ~ .,- ())
'" ()) ()) ()) ()) ()) .,- 00 '" '" .,- '" ~
~ <0 0 0 N 0 0_ .,- ~
>- ~ N ....- ,..: N ,..: 0
f- ()) ()) ())
0 ~ ~ ~ '"
- >- >- .,; L1i .,;
'" >- >- >- >- >- >- >- >- L1i L1i .,; L1i L1i
:;) (f) (f) (f) (f) (f) (f) (f) CfJ 0 0 ILl L1J L1J
N
'"
JJ
....
<9
~ 3
~ ~ iO --'
::. ~ 0 ~
~ N N S ~
0 N N iO
'" JJ JJ N 5>
0. .... .... ;f
." Co <9 <9 ~
" 0
.. ~ ~ ~ <9
a> S
Q 6' U 6' L1J t< 5'
0 ~
E 0 0 0 (f) S
~ t<
u: u: u: ::::J I- 3 iil 5' -
W- W- W- 0 Z --' ::::J ~ Q
" 5' - ;f ;f ;f 0 L1J ~ 0 0
:: :;; :;;
0 ~ e e e z UJ UJ -
"- "- "- 0 > <9 z 0 uJ
::::J ::::J :;) 0 0 0 f= .,; z :5 L1J ILl
0 0 0 z z z 0 "- z --' "- "-
t< t< t< 0 0 0 ti' I::i ~ L1J >- >-
<9 <9 <9 0 0 0 0 5' 5' e e
0 0 0 W- .,; CfJ 5' 5' 5'
ILl L1J L1J UJ I L1J ;[ ~ ~ ~ ~ ~ - -
CfJ CfJ CfJ f= f= f= f-- "- eo ::!.. ::!.. ::!.. ::!.. !C.. :;: :;; 5'
~ .,; .,; --' --' --' UJ CfJ 0 0 ~
'E. 'E. .,; .,; .,; t< .,; UJ L1J iO iO "i i\' i\' ~ ~ ::!..
I I I 0 f-- f- ~ ~
--' --' --' "- "- "- Z (f) UJ L1J 2- 2- 2- 0 0 ro
CfJ CfJ (f) ::::J '" '"
.,; .,; .,; .,; .,; .,; 0 0 0 0 iil iil iil iil iil OJ OJ ~
Z Z Z 0 I I
0 0 0 UJ UJ L1J UJ Z Z '" '" '" '" '"
> ;;: > 0 Z 0 0 ::::J ::::J ::::J ::::J ::::J 0 0 CfJ
f= f= f= .,; .,; f= :5 0 0 '2 '2 '2 '2 '2 l- f-- L1J
"- "- "- "- "- "- --' - - e- e- --'
0 0 0 '" '" '" .,; --' CfJ CfJ CfJ CfJ CfJ CfJ CfJ 0
L1J
ILl L1J UJ UJ L1J UJ I 0 (f) CfJ f-- f-- f-- l- f-- f-- f-- I
CfJ CfJ (f) "- "- "- CL :5 :5 L1J L1J L1J L1J L1J L1J L1J Z
.,; tli tli ::::J ::::J ::::J CfJ (f) --' --' --' --' --' --' --' .,;
OJ (f) (f) (f) .,; ~ 0 0 ~ ~ ~ ~ ~ ~ ~ :;;
0 .,- '" .,- 0 '" ~ ;; "' ;; N ~ ())
.,- 0 ~ '" <0 '" ;;
0 '7 ~ ~ '" ~ ~ '?
z .... .... ;::: "- m , '? 1" 1" 1" "? "? N
,;, ,;, ,;, ~ ~ ~ ~ ~
E " " " "- '" 6 6 ,;, ,;, ,;, ,;, ,;, ,;, ,;, ,;,
~ 00 00 OJ '" '" '" '" '" 0 0 N
N N N '" '" '" '" .,- .,- N N N N N N N .,-
.,- .,- .,- .,- .,- .,- .,-
..
15
N
~
"
"
=>
o
z
w
o
o
..
.,
..
"0
..
C,
-
..
>
ill
o
-
:;;N~
N_..
'" C ..
~Gl_
oE~
c en 0
1iiJl~
"0
..
o
0::
Q;
;;::
i5
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
V> V> V> V> V> V> V> V> V> V> V> V> V> V> V> V> V> V>
]j
0
....
..
"
'"
"-
-
'c
::>
"' '" N <D ..... <D 0 "' N ;D 0> '" '" en en '" ~ ~
'" ..... 0> '" "' '" 0 ..... '" N <D <D "'
<D '" <D ~ "' '" "'- ~ ~- "'- '" '"
>- <D ... cO ai <"i N- ~ ~ ~ ~ ... ...
....
a
- ~ <( <(
'c IL IL IL IL IL IL IL IL IL IL IL IL ~ <( <(
::> ill ill -' -' -' -' -' -' -' -' -' -' -' -' ill ill
;,.
N
0
....
0.. Co io 1::>
2- ~ ~ C
0 0 0 0
z z z z
::> ::> ::> ::>
c 0 0 0 0
0 io ;,. 1::> <0 N io ;,. 1::> N es 0:: 0:: 0::
"' ~ ~ ~ ~ ~ ~ ~ ~ t:. Z -' -' -'
c. ::::J ::::J ::::J ::::J ::::J ::::J ::::J ::::J ::::J <( <( <(
"5 <( <( <( <( <( <( <( <( <( ~ z z z
Ul 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0 0 0
.. ill ill ill ill ill ill ill ill ill 0 :-t. ~ ;:: ;:: ;::
0 .... .... i .... ~ i i i i ill 0.. 0.. 0..
E <( <( ~ 0 0 0 ~ Q. Q.
i! :;; :;; :;; ~ ill ill Z Z
-' -' -' -' -' -' -' -' -' CfJ CfJ Z
<( <( <( <( <( <( <( <( <( ::::J <( <( ~ ~ ~
z z z z z z z z z <( 0 0
0 0 0 0 0 0 0 0 0 0:: z z 0 0 0
;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ill ill ill CfJ CfJ CfJ
0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. i .... .... CfJ CfJ CfJ
Q. Q. Q. Q. Q. Q. Q. Q. Q. 0 0 0 0 0
;; ;; 0:: 0:: 0::
> > > > > > > > :::: -' ~ ~ ~
-' -' -' -' -' -' -' -' <( a a
:::> :::> :::> :::> :::> :::> :::> :::> :::> z '" '" z z z
a a a 0 () () () () 0 () () 0 0 ill ill 0 0 0
~ ~ ~ 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: ;:: -' -' ;:: ;:: ;::
!C-- !!- !C-- ill ill ill ill ill ill ill ill ill 0.. :::> :::> () () ()
5: 5: 5: 5: 5: 5: 5: 5: 5: Q. 0 0
ii3' ill ill ill ill ill
O? O? ill ill ill ill ill ill ill ill ill CfJ CfJ CfJ
fi,. CfJ f/) CfJ CfJ CfJ CfJ CfJ f/) f/) .... I I 0 0
2- 2- 0:: () () 0
f/) CfJ CfJ :;; :;; :;; :;; :;; :;; :;; :;; :;; ill <:'. <:'. z z Z
ill ill ill 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: > ill ill ill
-' -' -' 0 0 0 0 0 0 0 0 0 -' () 0 0 0 0
0 0 0 .... .... .... .... .... .... .... .... .... :::> > > ill ill ill
I I I f/) f/) CfJ f/) f/) f/) f/) f/) CfJ () 0.. 0.. 0:: 0:: 0::
Z Z Z ill ill ill ill ill ill ill ill ill ill ill ill ill ill ill
<( <( <( 0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. 0.. .... .... ....
" :;; :;; 0: 0: 0: 0: 0: "- 0: 0: 0: 0: 0: 0: ~ ~ ~
"' 0> '" '" 0 :r N '" "' 0; '" <D N "' '"
0 N 0; N ':' ':' '7 '7 -r -r -r -r N '"
<D '" ':' ':'
z N N N ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: " ;D ;D N N N
E .;, .;, .;, ~ ~ ~ ~ ~ ~ ..... '" '" ro
0 0 0 0 , , 0 0 0 ~ 0> '" 0> c:> 0>
.. N N N 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '"
'" '" '" '" '" '"
ID
o
M
~
"
"
"
o
z
w
o
o
<(
"
"
'C
'"
C,
~
"
>
UJ
g
t;N~
~~a:
cA4>-
oE':
o Cl 0
iiiJ;~
'C
'"
o
CO
a;
s:
o
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '"
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '"
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '" '"
l!
0
....
"
"
."
0-
~
'i:
::J
~ ~ N <t N r-- '" <Xl <t N N r-- '" 0; ..~ q> "" "'
'" "' r-- '" '" <Xl '" N
"' "' r--_ '" <Xl ~ N ~ ~
~ 0 ~ o-i o-i N
"' N
a
~ i~ > ....~. i~
'i: L5 L5 <( <( "- "- "- "- "- "- >- >- z "- L5
::J UJ W -' -' -' -' -' -' (j) (j) .... -'
>
.,. .'.
..
.....
"' N " co
W
~ ::c. ~ '" 1=
0' 0' 0' ~
z z z 0' ::J
::J ::J ::J CJ
0 0 0 Z ." i
" ::J
0 co a: a: 0 Ol
'" -' -' -' a: a: , -
c. <( <( < ::J ;
"f; Z Z Z -' () W
0 0 0 <( 0-
U> Z w- 0 i 1 t
" i= i= i= t3
0 0- 0- 0- 0 0 :
E <2- <2- <2- i= ~ i'2 ) >-
0- -'
11 z z Z <2- ~ ..:. ;Z Ol
-' :;;
~ ~ ~ Z :J' ~ -'
~ ~ W W
~ W w- LL a: (j)
0 0 0 UJ ;Z 0_ (j)
(j) (j) (j) .... W W W a: W <(
0 (I!. 0- a. a. UJ I() )
(j) (j) (j) t t t i'2 ~ 0 (j)- W
0 0 0 UJ :J' I ~ oa: CJ
a: a: 0:: 0 a: .... ZOl , ~
~ ~ ~ (I!. ~ () () 0' 0 <( -' <(J:
Ol 'E. ~
z z z W z '-'a: ):' :J' l 0
z z z UJ 0 0 a. 0 W '-' I
0 0 0 0 0 () () >- .... -' ::J Zw ~ ;;; ()
i= i= i= i= C ~ w ~ .... <.... Z
::J a: a: a: () Ol-' 0
() () () () S'- UJ a: w -i:i: 0 <
w Ol () < :;;
w w w w 1= 1= a: 0 w t: ':Jo 0
(j) (j) (j) (j) Z 0 W
-' ::J .... 0 0 I Z
0 0 0 0 ~ ::J ::J ~ U) () OlW eo. eo. ~ W
() () OlCJ
Z Z Z Z CJ CJ a: -' -' -'
w W w W 0 0 0 UJ <( a: W <( ::J(j) ~ ~ I ~
0 0 0 0 Z Z Z .... a. W .... eo.UJ
< UJ W 0 W en a.o
W W W W I < < a: (j) -' a: a: ~3 0 0 0
a: a: 0:: a: Ol Ol () "- ::J () W a: a: a:
W W W W W a: a: Z ~ 0 Z > < <( <(
I-- I-- t: I-- a. ::J ::J 0 I 0 <( a.() ::J ::J ::J
~ ~ ~ 0: -Z i
:;; () () () I-- (j) () a. a:- CJ CJ CJ
<Xl '" N "'
0 '" <t <t N '" <t "' ; ; "'
, ~ ~ ~ ';- ~ <t N N ';' '" , '" N
Z N N oJ- , N <h r-- .},
N ~ .}, N ~ ~
'" '" '" '" .}, 6 ~ 6 ';- .}, 6 .}, .}, '"
E m m q> m N 6 N 6 N N N '" '" '" .},
11 6 6 6 "' N N "' "'
'" "' "' "' "' "' "' "' "' '"
'" '" '" '" "'
<t <t <t <t
;e
"6
"
~
"
'"
::>
o
z
w
o
o
<(
..
..
"
..
c;,
~
..
>
UJ
o
-
~N~
~ C ~
cAlD-
oE,,:!
C '" 0
iiic1l1
"
..
o
a:
;;
;;::
6
a a 0 a a 0 0 a a a a
a a a a a a 0 a 0 a a
ci ci ci ci ci ci ci ci ci ci ci
'" '" '" '" '" '" '" '" '" a a
a 0
'" ci
'" '"
] "'-
0 ;;;
I-
a 0
a a
ci ci
a a
.. a a
u '" ci
'~ '" '"
n. "'-
- ;;;
'i:
=>
'" N a (J) '" ~ ~ N '" ~ N
"' ..,. '" r-- ..,.
0) ~ ..,. "'- (0
~ <6 ~ cO
(J)
a ~
-
'i: 1L 1L 1L 1L i'5 <( i'5 i'5 >- rJ) <(
=> ..J ..J ..J ..J W rJ) ..J UJ
c 6' 6' 6' 6'
0 z
'" z z z z rJ)
Q. Z Z Z w z
"5 UJ UJ UJ D- CJ
'" D- D- D- o Ci5
.. 0 0 0 b
C b b b ci l-
E 6" 6" cO cO ci ci z
6" 6" I- w
~ I- ~ ~ N '" :;;
l- I- !'!. !'!. , , , ,
!'!. !'!. ;-. ;-. w
~ ~ ~ ~ 0
~ ~ I I oJ oJ cO -<i z
I I " CJ ~ s - ~ 6' =>
CJ CJ W W UJ UJ UJ UJ w 0
Z Z
W W I I ..J ..J ..J ..J is 0 Z
I I CJ CJ CJ CJ Z
b b 0 ~ <(
b b <D cO z z z z 0 w
@. @. @. @. 0 z
'" '" !'!. z 0 0
, , ;-. ;-. ~ m m m 1L ~ ..J f=
e. e. ~ t:- a: ..J 0
UJ W W W :::J 0 <( :::J
~ m m m D- D- D- D- I- ..J rJ) a:
w w w w >- >- t >- W ..J '" l-
n. n. n. D.. t:. t:. t:. 0 <( w rJ)
t t t >- w w w w Z CJ !:: z
t:. l- I- l- I- <( Z 0
<( <( <( <( :;; 0:: >- 0
CJ CJ CJ CJ CJ CJ CJ CJ a: w ~ ~
z z z z w w w w 0 z
U U U U 0 0 0 0 1L I- 0 Z
Z Z Z Z Z Z Z z a: a: (j =>
UJ W UJ W W W W W W <( 0
LL LL LL 1L LL LL LL LL D- D- C( 0
0 0 a a '" '" ..,. (0 (J)
ci ~ N N ..,. ~ N N N ~ a 6>- (J)
~ N N ~ N (J)
z 6 6 6 6 6 6 6 6 ~ a ~S 0\
.,.
E ~ ~ ~ ~ <0 <0 <0 (0 6 0 00 (J)
6 6 6 6 6 6 6 6 r-- (J)
~ '" '" '" '" '" '" '0 '" '" 0 oC( 0
'" '" '" '" '" '" '" '" 0
a
o
.,;
o
o
,-:
'"
"'-
-
..
a a
a a
ci ci
'" '"
'" a
(J) ..,.
0 '"
..f
LL >-
rJ) 0
OJ
0:::- '" '"
Q) 13
'" '" 2
:;: 13 "E!
'" 2
0 Q)
0 OJ a.
~
Z '" !'!.
Q) ,~ ..
'" 1;5 ~
" .x
& UJ "
'0 c
0
ro ro 0
c =
Q) >
0 0 '"
E '"
c Q) Q)
'iij a: U
:;;
Q)
ro
CJ
c 1"
Q) '" N
" 6 6
" ~ a
CJ ~ ..,.
m
o
~
...J
;5 rJ)
0 UJ
I- a:
;;: =>
I-
;;:: U
C =>
<( a:
0 I-
a: rJ)
=
>- >-
a: a:
0 0
" "
W W
I- ~
<(
0 ()
.,
"
"0
"
C,
-
"
>
w
o
-
r- .,;
CONO::
~c:Q)
'G)..!
~ E nl
CI en ~
- " E
al"'g
"0
"
o
0::
;;
s:
(5
~
'"
"
::>
o
z
w
o
o
'"
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
<F> <F> <F> .. .. .. .. .. .. .. .. .. .. .. .. .. .. ..
:5
0
....
"
u
J:
-
';:
::l
u; OC> CD CD 0 " r- OC> 0 " 0 0 "' 0 0 N '" OC>
r- ;;; CD ~ N 0 CD U; '" N N N 0 0 0
N "- '" CD_ U; 0 OC> '" " " " " ~ 0 r-
~ ~ ci :;: <'"i N "" N-
" u;
a ~
-c-
- >- >- >- LL <C >- >-
';: '" '" '" LL LL LL LL LL LL Z Z
::l 0 0 (fJ 0 -' -' -' -' -' w -' -' (fJ -' -' 0 .... ....
!",<'
"
'",'
"
,
~ ;;;
0
'" a l':.
0. (fJ I
'i: a;-
u 10
"' 0.
" - '"
c ~ -C
(fJ
E <1> tL I
>
~ 8 N -
oil co oil
-
"0 d ,,- l':.
<1> '"
-c (fJ "0 '"
:0 ~ :0 "' 10 "m ro ~ ~
a;- E tr "0 ,
'" ~ '" ~ <1> m "'
Ui " => Ui => <1> 0. il tr <1> i"
U => LL ~ a. CI!. "0
U " "E => 0
.c 2 U .c - '" ~ " .c
<.) .s "' <.) - > '" u u
'" "0 1h 2 '" <1> ~ b <1> '" 6 (fJ
Qi >-
0 "' '" il 1h 0 0. 0: '" <.) oil
0. .0 a. 0. >- t3 '" iD -
=> '" 0- .0 t:. - oil ~ ~ '"
0- CI!. <1> => => 0- <1> <.) ~ ~ ~
:::- ~ ~ CI!. CI!. :::- w "0 m 0 "m <1>
"> "' E <1> W E '"
<1> E t3 tr 0 '"
.'!J 0 0. .c tr 0- <1>
.'!J <1> 0 OJ OJ OJ '" ~ '" "' ]i 0 <.) '" y <Ii
l" " 0 <1> " <1> <1> 0 ~ "c
t3 >- rn it' ro "
<.) " ii5 ii5 ii5 '" 0 0 " "S "0 :0 ~
~ z ro '" a. c .0
C 0 0 '" '" '" "0 "0 - LL '" ,= '" => 0
0 0 0 .'!J c c ~ " <1> "0 "' E 0- C (fJ '" ii5
0 u:: "00 .~ "e "0 "' "' '" .!!! <1> <1> ,~
~ "' "' => (fJ w ci ci '"
= 0 .2 i" i" 0 0: ~ 1h c
"' "' <1> 0- .2 .2 -' E <.) t3 i" i" i'j
"' "' '" E c c c 1h 1h 1h 1h it' a>
'" '" :g "w "w W <1> <1> => '" C "0 "- "- "0
(3 (3 "' 0 a: a: <1> " ;;: ,= 0 a> i2 i2 "
0 tr tr '" .... .... 0 a. '"
0 '"
z 0 ... '" ... '" co
- u; 1" "? q> - ,;- c\ ~ - '?
E N '" " , co " 0 , <9 "
~ '" - - ~ co - - ... ... "? ~ co ...
c\ c\ 6 c\ Jo Jo Jo 6 Jo Jo , c\ c\ , c\ c\
"' - 0
0 0 0 0 :;: :;: "' "' "' "' CD N N N co '" '"
" " " " " " " " " " "' "' "' "' "' "'
"'
a
"'
~
"
"
=>
o
z
UJ
o
o
<<
a
a
0
a
a
0
<D
Iii '"
...
0
I-
a
a
0
a
" a
" ci
;t <D
'"
~ ...
'i:
=>
>-
I-
0
~
'i:
=>
"
0
"'
C-
"t;
~
"
0
E
~
UJ
()
Z
~
0
-"
-"
<(
U)
UJ
0::
=>
I-
()
:::>
0::
I-
U)
ci 'I-
a()
Z ~:::>
E '0::
" ()I-
'" ()U)
"
"
'C
..
2>
"
>
W
o
~
&;N~
~t:i
chCl)-
oE1'!
0"'0
- " E
lXl"',g,
'C
..
o
a::
Q;
;:
(5
o
o
o
o
o
o
.,
'"
...
..J
~
o
I-
'"
W
a::
=>
I-
()
=>
a::
I-
'"
=
>-
a::
o
"
W
I-
0<(
()
a a a a a a a a a a a
a a a a a a a a a a a
0 0 0 0 0 0 0 0 0 0 0
... ... ... ... ... ... ... ... '" ... ...
.
'" en t-- ~ " " <D en a a a
N " ~ <D :;: :;: a
~ t-- N
N
U) U) i'5 i'5 i'5 <( <( i'5 u.. u.. u..
<( 0<( UJ W -" -" -"
0
<(
0
0::
u..
0
0 w
z :::> W
i=' w ..J
i=' uJ al =>
i=' U) '" UJ " ..J
0 D- > al
u:: U) D- O >- F= () "
0 D- C ~
U) D- W , () ()
N ..J F= 0 UJ al ~
W C9 ..J
~ ..J ..J UJ u.. lU ~
z C9 z :::> I- UJ al
<( Z ~ 6 z 0:: t:: 0 lU
I u:: :::> I ..J t::
'!!. W W 0 0 ~ ..J
I- U) t:: 0:: I
"' W I- ~ :;;; UJ ~
U) z I- 0 C
U) N <( l-
N > () () :::> w :J a:: a::
w 0 U) 0::
~ ~ 0 0 w 0 0 " "
:;;; ..J ..J -" ~ I- '!!.
l- I- UJ UJ W (') z '!!. '!!.
U) U) [l; [l; [l; Z 0:: UJ ()
0 0 u; UJ ::;: F= UJ UJ
D- D- Z Z Z '" UJ D- D-
UJ UJ ~ (') ~ 0::- 0:: > U) QO QO
-" -" U) u; U) 0 ~ <( ~ l- I-
(') (') ~ D- D- U) U)
Z Z (') (') (') a:: 0 () ()
u; u; Z Z Z I- UJ :;;; u: u:
F= F= F= z () '"
Z Z W 0:: u.. u..
U) U) U) :J , a:: UJ ~ ~
(') ~ X X X W al <( I
u; U) UJ UJ UJ 0 0 :;;; l- I- I-
~ 'i' ~ N N " ;0 ;0
'" N ~ '" t--
a 0 0 0 ~ '" .0 0 'i'
<t 'f <t 'f <t .0 0 N 'i' a
'" a '" '" a .0 a '"
a a a t-- t-- a ;::
t-- t-- a co a co ;:: ;::
t-- ,- t-- t--
m
o
t--
'"
"
z
i2
a::
0<(
::;;
I-
Z
W
::;;
W
;;:
a.
o
Z
0<(
"
Z
Z
S!
'"
>-
a::
o
"
w
~
()
~
"
'"
::>
o
z
w
o
o
'"
"
"
"
..
E>
"
>
w
.s
... -c
.,"'1>:
'" -"
"i' c "
","-
oE~
o C> 0
- .. E
lllCllg
"
..
o
I>:
;;
;;:
6
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
<F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F> <F>
j!
0
>-
"
u
~
'"
c
::>
.i'- N N ~ "' ;:; '" ... q> .g i~ N '" ro
N ~ '" 0 <D
'" 0_ "'. N ~
~ .,: ~ ~
a
..
....
- I~ a :2 :2 :2 .ii.~. :2
'" "- "- "- ~ "- <( Lii
::> z z -J -J -J l? -J W z
/1
i
c le- J
0
., en
0.
'C W
u le- z
'" ~ ::J !
.. ~ en
0 w iL w le-
a N io 'r 0 w en
E >- -J le- le- ~ ~ ~ ;z :; l? '5: Q
,1! I -J <fJ <(
~ w Q Q Q Q Q i l? <fJ a ::J
C- o ~
::J ::J ::J ::J ::J ~ 'r <fJ 0::: a
W W a a a a a 0 - W 0::: ""-
- ~ $
<fJ <fJ ""- ""- ""- ""- ""- ~ t:\ ~
a a W W W W w- w- w- w- w- a
z z t: >- >- t: t: t: >- I t: t: -J
0 0 :r: I I :r: :r: :r: I :r: :r: -J
z Z ~ ~ ~ ~ ~ ~ ~ ~ ~ w
:5 :5 c-
<fJ g Q Q Q Q Q Q Q Q Q Q
"'" >- >- >- >- >- >- >- >- >- >-
>- >- ""- ""- ""- ""- ""- ""- ""- ""- ""- ""-
z z U U U U U U U U U U U
;;: ~ F F F F F F F F F F F
D.. <fJ <fJ <fJ <fJ <fJ rn rn rn rn rn rn
w w :5 :5 :5 :5 :5 :5 :5 :5 :5 :5 :5
> >
F F D.. D.. D.. D.. D.. D.. D.. D.. D.. D.. D..
U U a a a a a a a a a a a
w w :2 :2 :2 :2 :2 :2 :2 :2 :2 :2 :2
-J -J 0::: 0::: 0::: 0::: 0::: 0::: 0::: 0::: 0::: 0::: 0:::
"- "- w w w w w w w w w w w
w w :r: :r: J: :r: :r: :r: :r: :r: :r: :r: :r:
0::: 0::: >- >- >- >- >- >- >- >- >- >- >-
0 '" 0 '" "' N a; ~ ~ l ~ N a;
r-C r-C ~ ~ N c? c? '7 "f "'
z <1 '" .;, .;, .;, '7
E '" 6 '7 '7 '7 '7 '7 ~ ~ ~ ~ '7
,1! r::: r-- ~ ~ ~ ~ ~ r::: ~ r::: r::: r:::
r::: r::: r::: r::: r::: r-- r:::
;<'
o
w
~
"
::;
::>
o
z
w
o
o
'"
0 0 0
0 0 0
0 0 0
'" '" 0
0
.n
l! w
0
I-
0
0
0
0
" 0
u ",-
'~
0.. W
-
';:
:;)
N ;;;
0
'" "'
~ '" <<i
0
-
';: "- "-
:;) -' -'
C
0
'" UU
,9-
~ 0
Z
0 ~
" <0
" e ~
E 0
0 0 -'
~ -'
:J :J '"
0 0 f/)
~ ~ (')
~ ~ z
52
0 0 no
-' -' '"
-' -' ::;;
UU UU
C. C. f-
0 0 Z
UU
f- f- ::;;
~ ~ W
0 0 >
'"
>= >= 0..
f/) f/) "
:'5 :'5 z
0.. 0.. '"
0 0 (9
::;; ::;; ~
no no z
UU UU Q
:r: :r:
f- f- f/)
;;; ::;;
0 ;;; 0..
~ f/)
Z J, J, 6
E '7 '7 "'
~ ~ ~ m
;::: ;::: 0
0
u;-
"
..,
~
"ij,
-
"
>
w
S
~N~
N_"
"I C "
Q> " -
oE,=
" '" 0
- " E
Ol"'g,
..,
~
o
~
c;;
;:
<5
o
o
d
o
o
..;
~
...
0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '"
0 "' 0 ..~ 0 ....~ ..,. ;;; :;;
;;: N 0
"l: ~ N <0
~ 0
N
J
"- "- L1- "- "- ..~ 0:: "- '"
-' -' -' -' -' I -' uu
.
'.
0 0 w X
~ "
<0 z z z 0 0
:;) ::> ::> ::;; '"
z 0 0 0 -' -'
'" N no no ::;; (9 -'
:r: (') ::>
f-- ;; (') w f/) ~
w no (9
f/) 0 > w (9
f/) f- 0 " " ::> ;;;
w '" z "' f'o.
-' <0 ~ 2- Ee- ci
~ ~ 0.. f/)
is e. ;;; ;;; ;;; 0 w
"' X
W uu f'o. f'o. f'o. J, 0
no no f/) f/) f/) ;;; ;;; N '"
0 0 -' -' -' f'o. f'o. ;;; z
'" '" '" 0
'" '" z z z -' -' f'o. >=
-' -' (') Q (9 '" '"
'" '" z Z f- 0
Z Z OJ f/) OJ (9 (') 0.. Z
0 0 t: t: >-' OJ OJ 0 ::>
>= >= :5 '" ,
::> ::> W W ""
0 0 " " " -' -' u: -'
w w z z z '" '" '" -'
no no 0 0 0 6 6 '" ::>
is is 0 0 0 0 0..
';' N "' ~ ';'
~ ~ J, t'- N ~
~ ,
.}, .}, ~ ~ ~ N N ~
c\ , 6 .},
"' co 0 '" '" .;,
co co '" '" '" <0 <0 '" '"
<0 <0 <0 <0 <0
~
o
m
..J
'"
f-
0
f-
'"
Cl
z
52
~
'"
:0
f-
Z
w
:0
w
> z
'" 0
0.. ~
o<l
Cl
z :J
Z '"
z
Cl Cl
(jj (jj
I
- <:
>- >-
~ ~
0 0
Cl Cl
W W
f- !;(
'"
0 0
~
"
"
=>
o
z
UJ
o
o
"
..
"
"0
..
C.
-
"
>
w
o
-
t;N~
'" -"
"' C "
cAcu-
oE~
C '" 0
- " E
tll"'g
"0
..
o
~
a;
;;::
6
0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0
w w w w w w w w w w w
]j
0
I-
"
"
'"
0-
-
'"
:;)
N "'" 0> "'" N N '" ~ '" ..~ Cl> >.'" 0> <0
"'" 0 ~
~ N-
O
,
- <( (/) <( <( ~ <( ~ <( ~ ~ ~
'" U- (/) U)
:;) W <( ...J W W W W <( <(
C2
l- I
z
0 I-
C9
U Z
>- UJ
!:e- ...J
0' N
~
Z Z ;:-
:;) ~
c 0 W
0 0:: "- t
"' C9 >- ~
0. 0:: ~ 0'
oti w
~ 0 z ~ w
" 0 z 0 Oii Oii Oii Oii Oii ~
C 2- U- ~. ~ ~
;:: ;;: !::. !::. !::. !::. Oii Z
E "- if) ~ Z !::. S
~ 0 ...J Oii '1 i'< '" ;;:- C9 0' 0
0:: <( (/) U) (/) ! ~
!::. ,!, ,;, "' en w 0
w z 0 I-
tll C9 0 0 0 w ~
'2'- (/) 0 ;:- , z
~ Oii w :i; :i; :i; :i; , :;)
...J ...J ~ 0
w !::. 0 0:: 0:: 0: 0:: <( ~
Oii u "- <( <( <( <( ti ~
!::. '> w W ...J ...J ...J ...J W ~
0:: I- C9 C9 C9 C9 "- , Oii
(/) 0:: 3: ill ~ ~ ~ ~ ~ I- l !::.
w ill
X (/) 0: U
ill U >- >- >- >- >- w (/)
0 0:: U Z ...J ...J ...J ...J ...J (/) : ...J
m ill ~ m ell m ell m <(
z S 0 " " " " " '"' z
U
0 0 ill ill ill ill ill ill ...J ~ ~
;:: "- U) 0 (/) '" (/) (/) U) <( U)
ill (/) (/) (/) (/) U) z
U ...J ...J (/) <( <( " <( <( C9 ( z
z <( <( (/) " " " " " en , <(
:;) u U ill a:
~ a: a: 0:: 0:: 0: 0:: 0:: U ~
0: <( <( <( <( <( I-
"" l- I- l- ii: [/)
...J U U [/) l- I- l- I- I- U- L ill
...J ill ill ill (/) (/) [/) [/) (/) C;; 0
:;) ...J ...J 0:: <( <( <( ~ <( f ill
"- ill ill "- " " " " I- "-
N 0 N '" "'" 0> ~ ~ ! j
c:i '" N ~ 0 0 0 0> <? 0;
'7 ~ ~ ~ ~ ~ ~ ~
z N ,
~ ~ d> ;;; ~ ;;; ;;; ~ ~
E , , 0'> 0'> ,!,
'" 0> '" d> d> d> d, d, 0
~ '" '" ;;: co
<0 <0 '" "'" "'" "'" "'" "'" '" <0
<0 <0 <0 co <0 co <0
~
'0
"
~
"
"
::>
o
z
w
o
o
""
Ui'
..
'tl
..
C,
~
..
>
w
.9
~fN~
~~~
cAG.l-
oE~
ClC>O
- .. E
lIl"'g
'tl
..
o
~
Gi
s:
<5
0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 ~ 0 0 0 0 0 0 0 0 0 0
yt yt yt yt yt yt yt yt yt yt yt yt
~
0
>-
..
"
'E:
l1.
-
'E
:J
'" jgj ~ "' Cl> '" '" '" <D '" '" '" '" '"
~ ~
~ !
0
!, ,
- <( <( <( Ufi <( LYi LYi <( <( OJ LYi LYi <(
'E OJ
:J <( W W W W W W <( W
, /:'
,
:,
.,'
"
;;0
;;0 ~
~ w
~ - 0
( '" -" ;;0 ~
'" '" ~
c\ 6 ~
t 0:: <( w
~ i=" :i ir :0 >-
w ""
" ~ 0 '" ." ." Z
0 W ~ - '" '" OJ
"' OJ OJ :i 9 0 >- I z
0. N w :i J, -'
"5 ~ Cl '" "' '" a
ui il <3 '" '" :0 I ;::
'" 6' w OJ 0 "- "-
.. w w a tL w ;:: >- >- w '.~ <(
Cl ~ ~ OJ :0 Cl tL W LL LL OJ 0
'> w Cl 3: 3: OJ ~ Z
E :J <2- <( I
~ Z tL -' Z tL ~ W ::)
S w ~ :0 >- >- er: tL :0
" z ::) ;;0 z z w t- :0
a 0 :J ~ ;;0 -'
z z ::) ::) -' a
Cl <( ::) -' ~ a a a
>- ~ :'2: ~ OJ ;;; ~
z t:. ::) w >- :0 :0 er: ~
:J ;;0 ;;; ;;0 -' ::; -' w w >- >-
a ~ ~ ~ :5 '" '" -" -' z (f) (f) z
:0 :0 a a a w w w
~ OJ OJ (f) : (f) w W tL tL 0 ir '" :0
"" w w w w OJ (f) er: er: w tL
- ir ir '" ! '" OJ (f) a a '5
(f) <( <( a a ~ (f) (f)
<( <( <( <( >- >- (f) (f) a
-' ::; ::; ::; ::; er: z 0 0 w
<( ~ a (f) w w
z X X X X a w w 0 0 -'
CJ ::) ::) ::) ::J >- ;:: >-- >-- 0 0 0 a
u; <( <( <( ; <( 0 0 w w ::; <( <( er:
~ w w 0 0 a >--
z 0 0 0 0 >-- >-- z z (f) er: er: z
<( <( <( <( <( w w <( <( w w a
w w w l w 0 0 0 -' -"
'" '" ir -' -" 0
I I I I W W W a a
>-- -' -' -' -' -' -' >-- >-- !;: er: er: :0
(f) <( <( <( <( 0 0 (f) OJ W
W W W ::J >-- >-- >--
0 z z z z I I 0 0 >-- z z (f)
w CJ CJ 52 CJ w w w w 0 a a >-
tL u; u; (f) u; > > tL tL <( 0 0 (f)
ci <D r-- ! r-- ~ "' 0 "' r--
0; 0 ~ ~ ~ 0 0 <D
Z 0 0 0 "- "- '" ~ ~ 0
'" ~ '" , J, , ~
E N d, d, d, d, r-, r-, "' "' '"
<D <D '" do do
~ "' "' "' "' ill "' '" '" co <D 00
<D <D <D <D <D co <D r-- r-- r-- <D
<D <D <D <D <D
m
o
;:
~
"
::;
::>
o
z
w
o
o
<(
"
..
'C
..
C>
;
>
w
.s
t)N~
'" -..
'" C ..
d,Q)-
oS":
C Cl 0
- .. E
Ill(/),[
'C
..
o
0::
a;
s:
6
'" '" '" '" '" '" '" '" '" '" '" '"
'" '" '" '" '" '" '" '" '" '" '" '"
0 0 0 0 0 0 0 0 0 0 0 0
"" "" "" "" "" "" "" "" "" "" "" ""
:a
0
I-
..
"
'i:
0..
-
'c
::J
.,. ." -c> '''' '" 00 .,. -ill ..~ N ~ N 00 N
N ~
~
CJ
....
- <( US US US <( <( US <( <( <( <( <( <(
'c <(
::J W W W W W W W W W W
..
....~ z
;;;; 0
~ ~
~ >: 0
z
w --' ::J
0 III 0
C 0 :;; LL
:;; w
,9 (fJ (fJ
c. (fJ (fJ (fJ
'" <( W
'i: LL ...~ ;::c ""'
" z w
'" I- >: >-
.. u w
c i= >- :;; w (fJ --'
--' III
E 0.. --' >- I "- (fJ :;;
0 '" --' ::J u :;; <( >-
~ :;; --' w
0:: : '" <( ~ 0 I- III (fJ
W : w :;; OC S!- w :;; (fJ
(fJ W Z
'" (fJ (fJ ::J <( iii w <(
!S i <( (fJ III >- rf) Z
Z --' <(
<( rf) <(
I- 0 I- 0 III S!- <( >-
<( U :;; OC --'
z z '::i 0:: III
W , W <( W W >- I-
:;; : I OC --' 0:: 0 (fJ (fJ 0 (fJ :;;
( ;:: e. (fJ (fJ I- w W
"- ;;;; --' I- 'E. <( <( U 0 rf)
<(
::J ~ Z rf) (fJ ~ ~ 0:: 0:: W w (fJ
0 W W I- "- <(
(fJ C9 0 0 W W W W W
W w en w w w w --' --' 0 0:: w
--' OC "- "- e- O --' --' 0 0::
0 U 0 0 w I- ~
0:: <( u: --' --' --' --' 0:: 0:: --' U
I- ::J ! LL <( <( ;; ;; l- I- S< w z
z X i <( z z z Z I l- ii:
0 ::J 0:: U C9 0 0 0 0 W W
U <( i I- en en :;; :;; U U > 0 (fJ
:;; :;; W W W W W W W W W W
W W > > > 0:: 0:: > > > > >
l- I- l ! 0 0 0 W W 0 0 0 0 0
(fJ (fJ :;; :;; :;; --' --' :;; :;; :;; :;; :;;
>- >- W W W 0 0 W W W W W
(fJ (fJ 0:: 0:: 0:: "- "- 0:: 0:: 0:: 0:: 0::
.; <D <D i ; 0 0 , N 0 ~ '" '" '"
Z ~ '" ~ ;;; '" ch "? 0 <D ';- ro
~ 0 0 '" '" "' 0 0
E 0 .}, 0 0 0 0 0 0
00 00 0> 0> 0> 0> 0> 0> 0>
~ (0 (0 (0 0> 0> (0 0> (0 (0 (0
(0 <D (0 (0 (0
~
o
'"
~
"
"
:J
Q
Z
UJ
Q
Q
<(
0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0
0 0 " " " 0 0 0 0
'" '" '" '" '" '" '" '" 0
0
'"
'"
'"
~
0
I-
0
0
0
0
.. 0
" '"
't: '"
Q. '"
~
'c
::>
'" '" ..:':: .'" ~ ~ " ..;:,
~
a ,
~ <( <( ~ 00 00 00 00 <(
'c
::> w w <( <( <( <( w
"
0
.,
c.
't:
" I-
.. z f='
.. w z
0 :2 f=' ::>
E 9, z 0
11 ::> ::> :2
0
0 :2 0
w <(
-' 0 w
0 <( w Z J:
Z z :2 ::> oc
0 oc oc 0 w 00
::J en <( w w oc > w
(]) z > > '2. Q 0
<( 00 I- W W V z
0 ::> ~ -' -' z z <(
0 i= i= oc
0 :2 0 0 0 s
z w z z 0 0
<( z ::> <( <( <( <( "' 0
:) -' 0 0 ~ -'
t:: o! w w -'
::> -' 0 0 (ll (]) <(
0 w -' <( <( 0 0 ;;;; z
<( w w ~
z 0 Z J: J: Z Z 0
0 00 oc oc oc J: J: -' i=
0 ~ w w w 00 00 w ;S
w W I- > > :) :) z
> > ;:: 0 0 <( ::J
u.. u.. a. <(
0 0 z z-
:2 :2 z z z z z
w w 0 0 0 0 0 0 0
oc oc en en en en en en en
0 0 ~ N ~ N co , -' .
0 ~
Z 0> 0 , ~ ~ , , , 0<(
~ '" '" 0 0 co :\lz
E 0 0 d> N N 0> m "T '0
11 m 0> m 0 0 0 0 0 0_
'" '" '" 0 0 0 0 0 000
l'- l'- l'- l'- l'-
"
..
"0
..
~
..
>
w
o
~
t;N~
~~a:
en 4)_
oE]!
0'" 0
mc%~
"0
..
o
oc
ai
;:
6
o
o
ci
o
o
'"
M
...
0 0 0
0 0 0
" 0 0
'" '" '"
0 0 N
l'- 0>
"' 0>
,..: "
" ~
u.. u.. <(
-' -' w
0 0-
z "
i= J: W
J: 0
0 00 0
::J 0 i'"
iO > -'
e:- O
c:i 0' >
z >-
0' z oc
::J C'l
W 0
~ oc z
0 0
::J oc 0
00 w w
0 ~
z z
;;;; 32 ;;;;
~ ;;;; ~
~ oc
oc w
0 t:: l-
i- ::J Z
0 0 W
::J Z 0
0 0 0
z 0 <(
0 0
0 N -'
N ~ ~
~ ~ ~
N "-
J, J, J,
;:: ;:: ;::
'"
'0
M
-'
<(
I-
0
I-
Z
0
i=
;5 0
:;
<( z
z i=
C) J:
iii C)
::J
2: :>
>- ~
oc
0 0
C) C)
w W
i- I-
<( <(
u u
~
..
"
=>
o
z
w
o
o
""
..
"
'tl
'"
Ci
~
"
>
W
.s
~N~
~t:i
en G)_
oEJ:
Q Cl 0
-"E
lIl"'g
'tl
'"
o
a:
~
6
0 0 0
0 0 0
0 0 0
'" '" 0
0
6
a
]3
0
~
0
0
0
0
" 0
u 6
." a
a.
-
'i:
:J
""' OJ
'<t '"
~
a
- <i ~
'i:
:J W
~
:r:
t9
W
:r:
t9
z
;::
Z
:J
0
::;
(:)
::!.
Z
t9
u;
w
Q
" ...J
0 <i
'" U
c.
"5 w
a.
'" rn
" :i;
Q
E :J
,1! & z
z ~
;:: :J-
...J~
:r: <iZ
t9 ~:J
~ ~o
ill if::;
~a:
Q Ww
rn ~Q
Q W...J
<i ...J:J W
0 0.0 0
~ 2:r: Z
Om ~
;;0 0::;
f':. llj", 0
...J
rn o<i ...J
w a.'" <i
x t9~ t9
0 ZW Z
OJ - ...J ;::
...J ~t9
...J :r:z :r:
:J t9- t9
a. :Jrn :J
0
0 ~ '<t o,~
~ ~
z .;- , "':r:
E ,}, '" '\'t9
0-
,1! ,}, 0...J
r--
r--
>
>-
a:
o
t9
W
~
<(
()
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '"
.
0 '" '" 0 '<t N '" r-- ~ '"
r-- '<t '<t 0 r-- ~
~
""' .0
N ~
"- "- "- "- <i <( <i "- <i <(
...J ...J ...J ...J W W W ...J W W
~ ~
u; u;
a. a.
0 0
'" '"
~ ~
ill ill
!< !<
~ ~
g g
;;0 ;;0
f':. f':.
Cii Cii
~ ,. ,. W W
'" a. a.
'" m '" ~ ~
'" m
"" '"' ~ m ~
, m ,. ...J ...J
...J ...J
0 (:) (:) ~ (:) '" <i <i
~ 0- ~ , m
(:) 8 rn rn
i2 ~ a: '"
'" '" 8 i2 , w w
w w w ~ ,. w (:) > >
s s S N 0 ~ 0 0
w w w 0 :s ::> 0 0
rn rn rn OJ 0 W UJ UJ
ii' ii' ii' ...J W W rn rn
w w w ~ <( ~ ~ <i <i
!< i i u W w
Q W ~ ~ ...J ...J
rn ~ a. w W
W ~ ~ 0 ~ '" '"
;:: 0 0 0 ;;0 ;;0 ;;0 '" '"
:J > > > oil ~ ~
;:: ~ ~ ~ "- ~ "- ~
if) if) >- >-
:J rn rn ...J ...J
::; oil oil ;;0 t9 t9 t9 t9 OJ (lJ
:> ;:; ~ "- ~ z z z z ::; ::;
w UJ w r:: r:: r:: r:: w w
>- 0 a. a. a. rn rn
a: ::; a: a: a: i:L i:L i:L i:L rn (/)
0 w <i <i
Cl ~ >- ~ >- ~ >- ~ >- W W
~ ~ ~ ~
W w :J :J :J :J :J :J :J > >
~ ...J ...J
<( a. ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:; ;:;
() a: ::> ::> ::> ::> ::> ::> ::>
N ""' '<t '<t '<t '<t '<t ,
N N N '" ""' N
~ <;' <;' <;' 'f '\' 'f 'f ~ ~
~ ~
6 ~ ~ ~ ~ ~ ~ r-- ~ OJ
N ~ ~ ~ '0 ' 0
0 6 6 6 , ,}, ,}, ,}, f2N f2N
en
~ en en en en en en '" 0 0
0 0 0 0 0 0 0 ~ ~
~ ~ ~ ~ ~ ~ -
'"
'0
~
o
o
o
o
o
o
'<t
'"
..J
~
o
~
Cl
z
;::
:r:
Cl
::;
~
"
"
::>
a
z
UJ
a
a
<(
"
"
'0
~
c;,
-
"
>
LU
.9
&;N~
N _"
'" " "
a, CI) -
oE'=
c 01 0
- " E
1ll0),g
"C
~
o
'"
"
s:
i5
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
'" '" '" '" '" '" '" '" '" '" '" <fl <fl '"
l'i
0
I-
"
"
'i:
a.
-
';:
:>
N '" '" '" '" '" ~ .... "' "' "' '" '" ~
~
a
- <( <( <( <( <( <( <( <( <( <( <( <( <( ~
';:
:> w w w W LU W W LU W W W W W
~ 0 c;;- oo ~ ~ 0 N (0
~ ~ ~ ~ ~ ~
(J) en en en en en en en en LU LU
a. a. a. a. a. a. a. a. a. (J) (J)
0 0 0 0 0 0 0 0 0 <( ~
"' "' "' "' "' "' "' "' "' w
~ ~ ~ ~ ~ ~ ~ ~ ~ --' --'
w w w w & & & & & w LU
'" '"
I- !;( !;( I- :> :;) :;) :> :;) '" '"
<( <( --' --' --' --' --'
g ~ g g ~ ~ ~ ~ ~ ~ ~
g g g g g g g g g g g N
~
;;0 ;;0 ;;0 ;;0 ;;0 ;;0 ;;0 ;;0 ;;0 ;;0 ;;0 iZ
!O:- !O:- !O:- !O:- !O:- ~ !O:- !O:- LL !O:- !0:- w
" iJJ iJJ iJJ iJJ iJJ iJJ iJJ iJJ iJJ iJJ a.
,9 (J) :;;
LU W LU W W W W LU LU LU LU
C. a. a. a. a. a. a. a. a. a. a. a. :;)
'i: i':: ~ >- >- ~ i':: ~ >- >- ~ >- a.
" l- I- l- I- I- ~ >-
'" --' -' --' --' --' -' --' --' --' --' --' LU- --'
" --' -' --' --' --' --' --' --' --' --' --' "'
c <( <( <( <( <( <( <( <( <( <( <( (J) :;;
0
E (J) (J) (J) (J) (J) (J) (J) (J) (J) (J) (J) I W
,1! '" '" '" '" '" '" '" '" '" '" '" (J)
LU W W W W LU W W W W W ~ (J)
> > > > > > > > > > > 5' <(
0 0 0 0 0 0 0 0 0 0 0 I- >- '"
0 0 0 0 0 S!- o 0 0 0 0 0
ill ill ill ill ill ill ill ill ill ill ~ --' w
w "'
(J) (J) (J) (J) (J) (J) (J) (J) (J) (J) (J) ;;0 :;; I
<( <( <( <( <( <( <( ~ <( <( ~ !0:- w 0
W LU W LU LU W W W W (J) '"
--' --' --' --' --' --' --' --' --' --' --' >- (J) 0
LU W W W W W W W W W LU -' <(
'" '" '" '" '" '" '" '" '" "'~ "'~ "' I-
'" '" '" Q:;~ Q:;~ :;; a. 0
'" '" '" '" '" '" w ~ w
~ ~ ~ ~ ~ ~ ~ ~ ~ ~~ %55 (J) I-
w
>- >- >- >- >- >- >- >- >- ::;a. ::;a. (J) w 0
--' --' --' --' --' -' --' -' --' <( --'
"' "' "' "' "' "' "' "' "' ",0 ",0 I- a. "
:;; :;; " :;; :;; " " :;; :;; :;;"' :;;"' z " w
w w w w W LU W W W w~ LU~ ;;; <( I-
(J) (J) (J) (J) (J) (J) (J) (J) (J) (J)>' (J)- (J) (J)
(J) (J) (J) (J) (J) (J) (J) (J) (J) (J)-, (J)::; 0 a. >-
<( <( <( <( <( <( <( <( <( <(OJ <(OJ >- " (J)
w w w w w w w w w w:;; w:;; I w W
> ;:'j > > > ;:'j ;:'j > ;:'j >w >w w I- '"
--' --' --' -' --' --,(J) --,(J) u:
~ ~ ~ <( ~ <( ~ ~ ~ <((J) <((J) '" t!
> > ><( ><( u: 00
'" "'
, , , , "" "" "" "" "" 0 0 ~
0 ~ ~ '" N ~
~ ~ ~ ~ ~ ~ ~ ~ do do ,
z '"
~ '" ~ 0 ~ ~ ~'" ~ '" ~'" ~o ~ ~ ~ '" ~ ~ ~
'0 ON ON ON '0 ' 0 ON ON ON
E :2'" :2'" :2'" ~ ~ ~
,1! .... .... .... .... .... .... 0 0 ""
0 0 0 0 0 0 0 0 0 .... .... '"
~ ~ ~ ~ ~ ~ ~ ~ ~ 0 0 U)
~ ~ ~
m
13
~
~
"
"
::>
"
z
w
"
"
"
0
0
c:i
Y>
]
0
I-
..
"
.~
a.
~
'~
:J
~
~
0
~ <(
'~
:J W
c
0
'"
0.
'~
"
'"
..
c
E
~ >-
--'
CD
~
W
(j)
(j)
<(
oc
W
I-
W
~
oc
W
I-
~
W
--'
CD
~
0
a.
;,.
,,;
z
E
~
..
..
'tl
..
2>
..
>
w
o
~
:;;N~
N~..
"1 c ..
","-
oE':
cO>o
- .. E
lXIUlg
'tl
..
o
a:
<i
;:
i5
o
o
c:i
o
o
ci
o
N
Y>
o
o
c:i
o
o
ci
o
N
Y>
..J
~
0
I-
Ul
W
W ;::
0 ::;
Z
~ ;::
:J
0 :;:
--'
..J
<( >-
(j) a:
w 0
;:: "
W
:::; ~
;::
:J U
..J
;::
:J
6
U)
m
0
0
o
o
ci
o
o
ci
o
N
...
0 0 0 0
0 0 0 0
c:i c:i ci c:i
Y> Y> ... Y>
N "' '"
'" 0 m
<O_ m "
~ ci -.i
'" "'
~
>- OJ U.
() ..J (j)
E
Q)
c
'"
E
Q;
a.
!!J !!J C
ro ro Ul .2
S S w 1ii
m 0> a: '"
c :J c
c =>
'c c I- 0
'" '" () u.
W W <( :J m
OC OC OC c
.. I- '6
- a:; 'E Ul =>
if> 2 l:! u
if> = C
'" (j) $ ~ '"
<( u C> <i' OJ ro
2 <Ii c 0 .. S
'0 ] ""
.. w 0 "
E 0 .9 w c '"
'E ~ c
$ c .0 ~ $ =>
<i' 0 iii => <i' 0
() oc Ul u (j)
!!J ~ '7 !!J C;
ro ~ ro ~
~ N ~ ~ N
'" 6 .0 '" t-
C 0 ;;: c "-
=> " => "'
0 0 U)
(j) (j)
m
o
m
Ul
W
I-
<(
Z
oc
W
I-
..J
<(
CONSTRUCTION BID
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
Oil Wen Road Widening. Segments 2 and 4A
BID NO. 09-5287
Full Name of Bidder MITCHELL & STARK CONSTRUCTION CO" INC,
Main Business Address 6001 SHIRLEY STREET, NAPLES. FLORIDA 34109
Place of Business 6001 SHIRLEY STREET, NAPLES, FLORIDA 34109
Telephone No. 239-597-2165
State Contractor's License # CUC046020
Fax No.239-566-7865
To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA
(hereinafter called the Owner)
The undersigned, as Bidder declares that the only person or parties interested in this
Bid as principals are those named herein, that this Bid is submitted without collusion
with any other person, firm or corporation; that it has carefully examined the locatfon of
the proposed Work, the proposed fOnTI of Agreement and all other Contract Documents
and Bonds, and the Contract Drawings and Speclficatlons_
Bidder proposes, and agrees if this Bid is accepted. Bidder will execute the Agreement
Included in the Bidding Documents, to provide all necessary machinery, tools,
apparatus and other means of construction, including utility and transportation services
necessary to do all the Work. and furnish all the materials and equipment specified or
referred to in the Contract Documents in the manner and time herein prescribed and
according to the requirements of the OWner as therein set forth, furnish the Contractor's
Bonds and Insurance specified in the General Conditions of the Contract, and to do all
other things required of the Contractor by the Contract Documents, and that it will take
full payment the sums set forth In the following Bid Schedule:
NOTE: If you choose to bid, please submit an ORIGINAL and ONE COPY of your
bid pages.
GC-P-1
(V)
"*'
::;;
::J .... 00 to .... a> ..... N 0 0 N
0 0 .... 0 ..... .... ..... a> 0 ..... "!
z ....: <<i iii ai -i iii ....: 0 ...;
W ....
..... N 0 a> N II) 00 ~ to II)
0 0 a> .... to ..... "'" a> N N
0 ..t N M <:5 N ....: <:5 ai en
<( a> 00 .... ..... M II) II) a> "'"
N "!. N "!. M a> 0 ..... 00
..t .... ~ .... ~ ~ en ~ en
.... ~ ~ .... ....
~ ~ ~
.....'t:l
CO nJ
N 0
..,0::
,
alGi
~;:
alO
Ul
Ql
't:l
..!!!
OJ
...
Ql
>
W
.s
Ql
~
nJ
.:.:
o
E
E
~
"'"
o
o
lD
d
z
I-
U
W
"")
o
0::
a.
~
z
~
o
U
0::
W
:::::i
..J
o
U
~
o U)
OlE
CIl Q)
1U~
u ",
... 11l
ca.
">-
0<(
E:s;
<(0
"'<(
"'0
~O:::
- U)
~E
02
Ol-
CIl ",
... 11l
8a.
...00
cw
"0:::
O::J
EI-
<(U
<;::J
...0:::
01-
1-00
",
11l
a.
00
(9
z
52
0:::
<(
:2:
I-
-z
~w
0:2:
ClW
CIl>
...<(
8a.
...0
Cz
5<(
E(9
<(z
<;z
0(9
1-00
U)
E
Q)
""
> U)
- E
~2
0-
01'"
CIl 11l
...a.
"'z
~o
c-
5~
E-
<(;;;!
-z
.lS(9
0-
1-00
>
~
o
g'E
102
u-
... ",
C 11l
"a.
0(9
Ez
<(I-
",I
0(9
I--.J
:>
~
o
ClU)
CIl E
1U Q)
u""
... ",
C 11l
"a.
000
Ew
<(I-
<;-.J
01-
I-::J
:>
lfl
CIl
";:
o
01
2
'"
U
I-
Z
:::l
a
::!;
<(
o
lXI
w
lJ)
<(
lXI
..J
<(
I-
a
I-
<(lXI
WW
1-1-
<(<(
zz
0:::0:::
WW
1-1-
-.J -.J
<(<(
lJ)
w
!;;:
z
a::
w
I-
..J
<(
00
:::l
..J
D-
o
1ii
w
00
<(
lXI
-.J
~
a
I-
0 0 0 0 0 <D 0 " 0 ;::: " 0 0 '" 0
0 0 '" 0 0 ~ " " 0 0 0 ~ " '"
0 0 M 0 0 0 ... ori 0 '" m 0 '" M '"
~ 0 0 N 0 ;:1; <D N '" <J"> '" N 0 ;;; " '"
" 0 ~ ~ 0 " N '" ~ ~ 0 " N
:a 0 ori M ori '" '" <J"> oi o:i a; oi ,,- ori 0
=> '" <J"> " <J"> ;;; <J"> '" ~ '" ;;; 10 '"
0 '" <J"> <J"> ;;; '" <J"> "
Z ]j <J"> <J"> <J"> <J">
"'
0 0
0 I-
'"
Uj"
"
'tl
'"
c;,
~
"
>
W
.g
f;;N~
~ca:
d,G)-
oE~
C C> 0
- " E
"''''g
'tl
'"
o
~
a;
s:
6
"
u
't:
c..
-
'c
:J
~
a
-
'c
:J
c
o
..
c.
't:
u
..
"
c
E
~
,;
z
E
~
~
c
<(
o
~
>-
~
o
Cl
W
I-
<(
U
o
o
ci
o
o
0"
M
00
""
o
o
(J)
-'
z
a
~
:J
iii
o
::;
,
;;
~
o
o
ci
o
~"
""
o
~
(J)
-'
(J)
z
:5
"-
~
:J
ro
(J)
~
z
~
z
~
W
o
'>
a
~
"-
~
,
~
;;
~
o
00
M
Sj
cO
c-
""
o
o
(J)
-'
I-
:J
a
>-
:5
o
z
<(
Cl
z
>=
w
>
'"
:J
(f)
Z
a
>=
o
:J
'"
I-
(f)
Z
a
o
w
o
'>
a
'"
"-
'i'
~
o
o
o
ci
o
o
".;
""
o
o
ci
"
M
c-"
""
o
o
M
o
::;
00
"
""
o
o
o
~
(f)
-'
(f)
I-
Z
W
::;
:J
Z
a
::;
>-
w
>
'"
:J
(f)
"-
a
z
a
>=
:;;
~
w
(f)
w
'"
"-
w
-'
:J
o
W
I
o
(f)
I-
o
W
~
a
'"
"-
z
~
z
~
W
o
'>
a
'"
"-
'?
,
C;
~
'i'
;;
~
o
o
M
~
""
N
o
""
o
o
oj
<D
N_
"-
-'
'"
w
ii:
~
<(
ro
~
o
iii
'"
:J
I-
Cl
Z
>=
<(
a
-'
"-
~
~
"
o
~
"
0=>
cj
""
o
o
o
;::
"-
-'
~
w
ii:
'"
<(
(l]
~
o
iii
'"
:J
I-
o
W
"
>"
(f)
N
"
o
0.
"
ci
""
o
o
oj
'"
"-
N
N
~
"-
-'
w
"-
t.
w
o
z
w
"-
'::;
u;
o
w
"
>"
(f)
ch
~
"
o
o
o
ci
""
I
I
i
~
o
c-
o.
""
o
o
N
~
Cl
z
iii
ro
:J
'"
Cl
o
z
<(
Cl
z
ii:
L1i
-'
o
.'-
6
~
~
c-
oO
""
o
'"
N
N
",-
N
N
>-
o
'"
:5
:J
Cl
W
'"
z
a
>=
:;;
<(
o
x
w
~
6
N
~
o
0.
M
""
o
o
o
o
o
o
~
>-
o
-'
is
(J)
ro
:J
(J)
Z
a
~
x
w
1"
o
N
~
o
0.
~
""
o
o
en
<D
m
N
>-
o
-'
w
z
z
<(
I
o
z
a
>=
:;;
<(
o
x
w
'"
6
N
~
c-
~
cj
""
;g
cj
""
o
o
oj
'"
<D
oi
N
>-
o
>-
(J)
<-
N
"6
N
I-
Z
W
:;:
"
z
<(
(l]
:;:
w
ro
W
"-
>-
I-
Z
a
>=
~
:J
iii
>"
(f)
<D
6
N
~
1"
0=>
<D
~
~
"
"
"
a
z
w
a
a
"
Ul
..
'C
"
C.
~
..
>
w
.9
t;N~
~1:g:
cbQ)-
oE~
" '" 0
- .. E
Ol"'g
'C
"
o
<>:
a;
;;:
(5
<0 N N 0 '" "- "' <D "' 0 N :j: "- N N 0 <0 <D
0 '" "' <0 "- N "' '" ~ I'- <D 0 "1 I'- '" "' ""'
a:i ,,; '" oi oi ill oi N N a:i ,,; M '" :;;: a:i N ;;; M
u:; '" '" '" ""' '" 0 <0 N <0 0 <D <0 I'- <0 <0
'" "' ~ <0 '" 0 <0 "' <0 V <D "'- N 0 "'. V <0
ci ,..: N- '" oD '" as oD as as '" '" ~ oi '" ;;;; as ci
;;;; ;;;; "' 0 ;;;; <0 ""' '" ;); ;); <0 ~ ;;;; ""' ;;;; ;); ""'
v- a_ ~ "'- '" ;;;; ;;;; '"
]j ;;;; ;;;; ;;;; ;;;;
0
I-
.. '" 00 00 '" .,. 00 '" '" .,.
,!,! 00 M '" '" '" 00 .,. M '" 00 .,.
Ii: .,. 00 ,-.. S .,. '" '" '" 00 00 00 M '" ;'j 0; N <-' vi
M 00 M M '" 00 "" 0
.0 .0 <-' vi <-' '" <-' :: 00 '" '" 00 '" M 00 '"
- M '" 00 '" '" "', ",' 00.
'i: '" '" "" "" "" "" "" "" M N N M "" '"
""
~ '" "" '" "" "" "" "" '" ""
0 0 0 0 0 0 0 0 0 ,~ 0 0 0 0 a 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 C! 0 0
oi .; ill a:i M N '" N M !l~ '" .; M M N ~ .; oi
~ "' '" '" '" '" '" V <0 "' "' v "' ~
<0 <0 0 0 N 0 0_ v ~
a ~ oJ ,..: ,..: oJ ,..: ;;
'" '" '"
~ ~ ~ N
- >-
'i: >- >- >- >- >- >- >- >- >- " ~ ~ " ~ ~ ~ "
~ (j) (j) (j) (j) (j) (j) (j) (j) 0 0 w w w
N
N
.;,
I'-
(!)
~ ~
~ "1 <D -'
::: ::: 0 ~
" N N !!:- >-
0 N N "' I-
'" .;, .;, '>
"- I'- I'- N C2
." "1 (!) (!) 0
"
on ~ ~ ~ (!)
.. LL
" 0 G 0 w <>: 5"
E 0 I.
0 0 0 (j) !!:-
~ <>:
c;: c;: c;: ~ I- ~ en 5" -
LL LL LL Z -' "
C2 C2 C2 0 w ~ ~ I. 0
~ 5" c;:: 0 :2' 0 :2'
0 ~ ~ t:. t:. t:. z w w ~
"- "- "- 0 > (!) z 0 W
~ ~ ~ 0 0 0 ;:: " ;<; S w w
0 0 0 z z z 0 "- z -' "- "-
<>: <>: <>: 0 0 0 0:: I- ~ W ~ >-
(!) (!) (!) 0 0 0 -' 0 5" 5" t:.
0 0 0 LL " (j) 5" 5" 5"
w w w w ~ ~ - -
(j) m (j) ;:: ;:: ;:: W I ~ ~ ~ ~
" " " -' -' -' I- "- eo !'.- !'.- !'.- !'.- !C- :2' :2' 5"
~ ~ ~ " " " w m w w "' <D 0 0 ~
<>: " "i ii1 ii1 f: f:
I I I 0 l- I- eo eo !'.-
-' -' -' "- "- "- z m w w 2- 2- 2- 0 0 r0-
m m m ::J <>: <>:
" " " " " " 0 0 0 0 iD iD iD iD iD CD CD eo
z z z 0
0 0 0 w w w w z z <>: <>: <>: <>: <>: I I
;:: ;:: ;:: ;;: ~ > 0 z 0 0 ::J ::J ::J ::J ::J 0 0 m
" ;:: S 0 0 ~ ~ ~ ~ ~ l- I- W
"- "- "- "- "- -' - - 9- 9- -'
0 0 0 <>: <>: <>: " -' m m m (j) m m m 0
w
w w w w w W I 0 m (j) l- I- l- I- l- I- l- I
(j) m m "- "- "- "- S S w w w W W W W Z
" <1i <1i ::J ::J ::J m m -' -' --' --' -' --' --' "
CD m m (j) " ::E 0 0 z z z z z z z :2'
ci v 0 ~ v "' v 0 ~ "' u:; ~ ~ ;0 N :;;: '"
0 ~ ~ ~ ~ ~ ';" '7 <D <0 <0 <0 ;0
Z r:: r:: , , '7 l' l' l' "! "!
';- ~ ~ ';- cr, ~ ~ N
E "' .;, .;, " " " ""' 0 0 ~ ~ ~ ~ .;,
I'- .;, .;, , .;, .;, .;, ,
~ <0 <0 <0 "' "' "' "' ""' 0 0 <0 "' N
N N N ""' "' "' "' v V N N N N N N N V
V V V V V V V
,-..
N
15
M
~
"
"
=>
o
z
w
o
o
<(
"
~
..,
~
a,
~
~
>
w
3
f;;N~
~~~
cAl>>-
oE~
o C> 0
iiiJl!
..,
~
o
0::
0;
3:
o
t- t- <<> 0> 0> 0 ;;; 0> 0 '" '" <<> 0 <<> 0 0> '" t-
'" '" '" '" N '" 0 ~ <<> <Xl <<> N N 0 t- O> '"
"' <0 .. "' <0 00 m N m m m <0 N 0 .. oj N ~
t- N <Xl '" <Xl '" '" N <<> <<> t- t- ;;; N ;J; ~
0 0> 0 <Xl ~ '" 0 " 0_ "- '" <Xl t- <Xl '" N_
ri 00 ci 00 .e- ri '" 00 "' .e- ~ ~ ci <!S N ... ;;0
;;0 0> ;;0 0 '" <<> N N <Xl '" <<> '" N N '"
... N ;;0 N ;;l; <<> N ;;0 ;;0 N ... '" ... '"
] ... ... '" ... ...
0
I-
~ ~ '" ~ <-
" ~ '" '" 00 ;": '" ~ 0 ;": '" .,,- 0 ~ '"
'~ 6 0; :::j "1 .,,- '" '" '" 0 M .,,- <- 0 M '" -
11. '" '"' .,; N 0; .. ~ 00 ~ 0 '"' N
- '" '" 0 ;;; M ::; .,,- '" 00 Sj '" '" ::; .. .,; 0 .,,- "'-
'C; ",- N or; '" '" '" ... '" '" '" '" <A '" '"
'" '" <A '" '"
:> <A '" '" '"
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 ~ 0 0 0 0 0 0 ~ ~
.0 oj N <0 '" <0 0 .0 N <D m .. oj m m 00 ~ ~
~ <<> t- O> <<> '" <<> 0 t- <Xl N '" '" '"
'" '" '" ~ '" <Xl "'- ~ ~ <<>- '" '"
C1 <!S ~ '" ai ri N ~ ~ ~ ~ ",- ~
- <( <( <(
'c; LL LL LL LL LL LL LL LL LL LL LL LL ~ ~ ~
:> w w w --' --' --' --' --' --' --' --' --' --' --' --'
"
N
0
I-
l1. in '" Co
2- ~ ~ ~
0 0 0 0
Z Z Z Z
=> :> => =>
C 0 0 0 0
0 '" " Co (0 N '" " Co N ~ 0:: 0:: 0::
'" ~ ~ ~ :!. :!. ~ ~ t:. --' --' --'
Q. :J' :J' :J' :J' :J' :J' :J' :J' :J' z <( <( <(
.5 <( <( <( <( <( <( <( <( <( ~ z z z
'" i2 i2 i2 i2 i2 i2 i2 i2 i2 0 0 0
~ 0 i= i= i=
0 w w W w W w w w w :0. ~
I- ~ i i ~ i ~ i ~ W l1. l1. l1.
E <( 0 0 0 Q. Q. Q.
~ ::; ::; ::; ::; ::; ~ w w Z Z Z
--' --' --' --' --' --' --' --' --' 00 00
<( <( <( <( <( <( <( <( <( :J' <'i <( ~ ~ ~
z z z z z z z z z <( 0
0 0 0 0 0 0 0 0 0 i2 z z 0 0 0
i= i= i= i= i= i= i= i= i= w w w 00 00 00
l1. l1. l1. l1. l1. l1. l1. l1. l1. ~ l- I- 00 00 00
Q. Q. Q. Q. Q. Q. Q. Q. Q. 0 0 0 0 0
::; :<; :<; 0:: 0:: 0::
:'; > :'; ::i ::i ::i :'; > > --' ':'. ':'. ':'.
--' --' --' <( 8 8
=> => => => :> :> => => => z '" " z z z
8 8 8 0 0 0 0 0 0 0 0 0 0 w w 0 0 0
~ ~ ~ 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: i= --' --' i= i= i=
!!- :!- !!- w w w w w w w w W l1. => => 0 0 0
S S S S S S S S S Q. 0 0 w w w
0:;- <>;> <>;> w w w w w w w w w w w 00 00 00
r!:- oo 00 00 00 00 00 00 00 00 l- I I 0 0
2- 2- 0:: 0 0 0
00 00 00 ::; ::; ::; ::; ::; ::; ::; ::; ::; w "'- "'- z z Z
0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: 0:: ::i w w w
w w w 0 0 0 0 0 0 0 0 0 0 0
--' --' --' 0 0 0
0 0 0 l- I- l- I- l- I- l- I- l- => > > w w W
I I I 00 00 00 00 00 00 00 00 00 0 l1. l1. 0:: 0:: 0::
Z Z Z W W W W W W W W W W W W W W W
~ ~ ~ l1. l1. l1. l1. l1. l1. l1. l1. l1. l1. l1. l1. l- I- I-
a: a: a: a: a: a: a: a: a: a: a: a: ~ ~ ~
'" 0> <<> <Xl 0 l' N <<> '" 0 <<> '" N '" <<>
0 N cr; N ') ') '? '? 1" 1" 1" 1" 1ii N <<>
'" <>> ')
z N ~ N ;:: ;:: <- <- ;:: <- ;:: ;:: ;:: " <D <D N N N
E J, J, ~ ~ ~ ~ ~ ~ ~ <- <Xl <Xl <Xl
~ co '" , '" '" , '" '" '" , m <>> <>> m m
N N N 0 0 0 '" '" '" '" '" '"
'" .,,- .,,- '" <<> <<> <<> <<> <<> <<> <<> <<> <<>
'" '" '" '" .,,- " '" '" '" <<> <<> "" <<> <<> <<>
'" '" '" .,,- '" '"
t-
N
"6
.,
~
"
"
::>
::>
z
w
::>
::>
""
.,
"
'C
..
E>
"
>
w
.s
t;N~
~i:~
cA OJ_
oE~
C '" 0
- " E
tll"'g
'C
..
o
~
4i
;:
o
'" " t- ""' 00 0 ;;; 0 t- O " 0 '" '" '" 0 0 0
""' '< 00 "< oO " '" '" t- oO 0 '" '" 0 0 0 0
<0 a; '" ;::: ori ;;; <0 <0 a; o? --i --i "' 0 m 0 0 ori
oO '" 0 0 '" ""' '" '" '" '" 0 <f> 00 ;;;
00_ 0 '" t- '" ""' N 0 ~ N '" t- ""' 0 '" N
N <.0 '" ai <f> N- '" <.0 <.0 ",- e) <.0 '" <f> ,,- '"
;;; <f> <f> <f> '" oO ;;; oO t- '" ;;; <f> " ;;; <f>
<f> '" <f> <f> " <f>
:5 <f> <f>
0
I-
" N " '" '"
U M '" '" 'D '" '" '" "" '" " " '" '"
~ ." M '" <'- - ~ "" 'D ~ '" N 'D '" '" ~ '"
0: N "" "" 'D ~ '" M
~ vi vi " --i 00 00 N '" '" 0 ""
- "". '" - " 'D ~ "" ;;;; ~ " - ::;. 'D
'i: N ",' '" - - - - '" '" '" '" - - '" 'D
'" '"
:> - - '" '"
0 0 0 0 0 0 0 0 0 0 0 0 0 0 .......i~ l >! 0
'< 0 0 0 0 0 0 0 0 0 0 0 0 0 0
~ ~ N --i N '" m a; --i N N '" m a; ori
~ 0 oO t- o 0 '" 0 '"
'" oO ": '" 00 ~ '" ~ ~
a e) ~ '" '" N
'" N ...
., ..
..
- <( <( 5 $ :[.:::f.$
'i: ~ <( LL LL. LL LL. LL. LL. >- >- Z LL. <(
:> w w w --' -' --' --' --' -' (f) (f) I- --' W
>. .,..>
....... f'f> .
'f':i..
....ii> ,.>
.....
,f
>
>
.,.....
'" N " ~ >
w
~ :!. ~ i'o ~ ....,
5' 5' 5' ~
z z z 5' :> >.. ....
:> :> ::> Cl ..i.i...
C 0 0 0 z ""
0 ~ ~ '" ::> to >:~
., --' --' --' 0 ~
0. <( <( <( ~ ::> -
'C z z z --' () w
u 0 0 0 <( < a.
.. 0 ~
" ;:: ;:: ;:: z W C3 ii~
C a. a. a. 0 0
E Q. Q. Q. ;:: ~ "' ::;
a. ,
~ z z Z Q. , to
~ --' 52 ..,~
-' :;;
~ ~ ~ z ~ ~ -' i
2' ~ w w
~ w W iL '" (f)
0 0 0 w o~ , (f)
(f) if) (f) I- W W W '" 52 w I() <(
0 ~ a. a. a. w 0 . ~
(f) if) (f) ~ ~ ~ "' ~ (f)- w
0 0 0 w ~ I ~ o~ Cl
'" '" '" 0 '" I- ztO ~
~ ~ ~ ~ ~ () () 5' 0- <( -' <((t
to [e. ~
Z Z Z W Z "'''' :;- ~ 0
z z z w 0 0 a. w I
0 0 0 0 0 () () >- 0 I- '" ::> Zw ~ ~
~ --' I- <(I- ()
;:: ;:: ;:: ;:: t:. w ~
::> '" '" '" () to--' z
() () () () ~ w w '" () w ~u: 0 <(
w w w W to 0 I- ei :;; .~
(f) (f) (f) (f) --' ~ ~ '" z w I ~o w 0
~ :::J ::> ::> ~ 0 0 tOw eo eo z
0 0 0 0 () Cii () w
z z z z Cl Cl () '" tOCl
--' --' --'
w w w w 0 0 0 w <( '" w <( ::>(f) ~ ~ ~ ~
0 0 0 0 z z Z I- a. w I- eow
<( w w 0 w rJi 0.0
W W W W <( <( '" (f) --' '" '" 0 0 ~ 0
'" '" '" '" I to to () ::> () ~3 '" '" '"
LL. W
W W W W W '" '" z ~ 0 z :;c <( <C <C
l- I- l- I- a. ::> ::> 0 I 0 o.() :::J :::J ~ :::J
~ ~ ~ ~ a: _z
() () () I- (f) () a. "'- Cl Cl Cl
00 0 '" oO
.; ""' " " N 0 ;;;: oO i ~ oO
~ ~ ~ ~ ';- ~ " N '" ') '" , ""' '"
z N N N + ~ ~ N J, N ~ N ~ t- J,
~ ';- ,
E '" '" 00 00 J, 6 , 6 6 <6 6 <6 '" '"
'" '" '" '" 0 N '" <6
" 6 6 6 6 ~ '" N N '" '" oO '" '" '" "'
" "' oO oO "' "' "' oO oO "' ill ""'
""' ""' '" ""' "'
" " " "
~
N
o
~
~
"
"
=>
C>
Z
w
C>
C>
0(
N ..... '" 0 0 0 0 0 '" 0 0 0
'" ..... ..... '" '" ..... ..... 0 '" 0 0 N
a; a; ,,; 00 ,..: '" 00 0 0 0 0 ~
N '" V '" '" 0 0 '" V 0 0 <0
'" "'- N 0 0 O. N '" v_ 0 0
00 ;;; ;i ",- N ;;; ;;; ,..: u:; ,..: ci N
'" ;;; N '" '" '" '"
J9 '" '" N "'.
'" ;;;
0
f-
0
" 0 0 0 0 0 0 0
" N '" ..... ..... 0 0 '" 00
'i: 00 "0- "0- .,. -,; 00 vi '" '" 0 ~
0. ~ "0- "0- M 0
'" '" ;; 0 0 M 0 ci 0
- ~ O. M. 00 ;;:; 0 "'.
'" '" '" '" '" ..f M ,..: ~
::J '" ;;:; '" '" '" '" ;;:;
'"
0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 C! 0 0 0 C! 0
,,; N 6 a; ,,; ~ ~ N "' ~ ~ N
~ '" v '" ..... v
'" ~ v "'- '"
<6 ~ ,,;
a '"
~
-
'" LL LL LL LL US 0( 0( 0( >- (f) 0(
::J -' -' -' -' uu uu uu (f) -' uu
i: G" G" G" G"
0 z
., z ;;; ;;; z (f)
Q. Z Z Z uu Z
'i: uu uu uu 0. Q
" 0. 0. 0. 0
..
" 0 0 0 b (f)
C b b b 0 f-
0' 0' z
E 0' 0' f- 00 00 6 6 uu
~ f- ~ ~ N '" :2
f- f- ~ '!? , , ,
'!? ~ ;.- ;.- - ;.- uu
~ ~ ~ 0
~ ~ I I N N 00 '" Z
I I " " ~ ~ ~ ~ G" ::J
" " w w w- w- w- w- uu 0
z z
W W I I -' -' -' -' 0 0 Z
I I b b " " " " 0 z 0(
b b <6 00 z z z z 0 uu ~
~ ~ 0 z
,,; .0 , , ~ '!? '!? z 0 0
;.- - ~ ;::
~ ;( OJ OJ OJ LL -'
8- 8- ~ t:- '" -' 0
uu uu uu uu 0(
;( OJ iC OJ a. a. a. a. ::> 0 ::>
f- -' (f) '"
uu uu uu uu t. t. t. >- uu -' :2 f-
a. a. a. a. i::- 0 0( uu (f)
t. >- >- >- uu uu uu uu z " t: z
i::- i::- i::- f- ~ ~ ~ 0( z 0
0( :2 0:: ~ 0
" " " " " " " " '" uu >-
z z z z uu uu uu uu 0 Z f-
0 0 0 0 0 0 0 0 LL f- 0 Z
Z Z Z Z Z Z Z Z '" '" 0( ::>
uu uu uu uu uu uu uu uu uu rt 0 0
LL LL LL LL LL LL LL LL a. '" 0
0 0 0 0 '" '" "0- '" '"
0 ~ N N "0- ~ N N N "i 0 6>- '"
z ~ N N ~ N 0 ~
6 6 6 6 6 6 6 6 ~ ..,. :Jls m
E ~ ~ ~ ~ '" '" to '" 6 0 00 m
~ 6 6 6 6 6 6 6 6 ..... m
'" '" '" '" '" '" '" '" '" 0 0'" 0
'" '" '" '" '" '" '" '" 0
..
"
'tl
..
2>
"
>
uu
.s
.... -ci
",NO::
N_"
'9a;.S!
gEl:
cO>o
- " E
alrllg
'tl
..
o
0::
Q;
;::
(5
~
o
...:
....
o
.;
en
N
.;
~
...
..,. 0
~ 0
.0 <6
..... .....
N <0
.; ""
a '"
N
'"
a; 0
..,.
6 a;
;;; .....
..,.
'"
0 0
0 0
.0 6
'" ..,.
0 '"
.;
LL >-
(f) 0
~
r::- .. ~
~ u
'" 2
~
"0- U 1;;
'" 2 Q;
0
0 U5 Q.
~
Z 0> ~
" ,", "
0> 1;; 1ii
"0 .x
~ uu t3
'0 i:
0
<ii <ii 0
i: -
.. > -
0 0 on
E on
i: " ..
.iij '" 0
:2
"
<ii
"
c 1"
" '" N
"0 6 6
" ~ 0
" ~ ..,.
.....
N
'0
w
-'
~ rIl
0 uu
f- 0::
~ ::J
f-
;:: "
0 ::J
0( 0::
0 f-
'" rIl
=
>- >-
0:: 0::
0 0
Cl Cl
uu uu
~ ~
" t)
~
"
"
=>
D
Z
W
D
D
"
u;
..
'"
..
c,
~
..
>
LLJ
.s
t;N~
~c:1
cAa>-
oE~
C '" 0
- .. E
m<JIg
'"
..
o
<>:
Q;
;:
o
a oo t- a M " a ('oJ a a a oo 0) a a a a; "
oo oo '< a oo a <'"> a a a <0 '" a a <0 0)
N ,,; :; 0 o-i a; " 0 ,,; 0 <0 ro " N ro a; a; "
'" oo ('oJ a a '" oo oo ('oJ a ('oJ oo 0) <0 a oo
'" t- oo <'"> <0 t- N t- a ('oJ a a 0) 0) <0 0) " t-
N t-- c;i cD c;i 0)- as c;i N --i '" --i as --i c;i --i c;i "'
0 <'"> ;;; ;;; a ('oJ <'"> '" t- ;;; '" ;;; '" " " ('oJ oo ;j;
;;; ('oJ ;;; '" '" ;;; ('oJ '" '" '" '" ;;;
1; '" '"
0
f-
a <0 a a ;:: ;:: " a a 0 oo 0) a a a t- t-
<'"> <0 " a t- ('oJ ~ a ('oJ <'"> t- ~ 0) oo oo <0
N '" '" 0 0 0 0 o-i <0 0 N o-i a; '" <0 " " "
t- " '" ('oJ '" '" '" <0 oo t- ~ <'"> ;;; a 0) " t- <0
.. <'"> t- a_ '" '" oo ;;; '" ;;; '" ('oJ '" '"
u '" '" ""' '"
';: ;;; '"
0-
-
'e
::>
a a a a a a a a a a a a a a a a a a
a a a a '< a a a a a a a a a a a a a
,,; ro <0 <0 0 " '" ro 0 " 0 0 "' 0 0 N a; <Xi
~ t- M <0 ~ ('oJ a <0 oo '" ('oJ ('oJ ('oJ a a 0
N "- 0) <0_ oo a '" <'"> " " " " ~ a t-
~ c;i ""' N --i N
0 " :; oo
~
- >- >-
'e >- LL m CD CD LL LL ~ LL LL >- LL LL >- Z Z
::> 0 0 CfJ 0 --' --' --' --' --' --' --' CfJ --' --' 0 f- f-
"':
"
,,'
"
0 .-, ;;;;
"' a !'o-
0. CfJ I
';: a;-
u '"
'" 0-
.. '=- '"
C " .c
CfJ
E " "- I
>
~ is N -
o1l <'"> o1l
.-, ai
'" a !'o- "
" 0>
.c CfJ 12 0>
:0 a;- :0 V> '" "", ro ~ ~
~ "E C< '[;
'" 's ~ '" ~ " ""
(i) ~ (i) ~ " 0- W <>: T "
tl tl ~ LL " Ci '!!- " (;
.c 2 tl .c - 0> " ~ ro " 1 .c
" 2 V> " " > <3
'" 1;; '" 1;; 2 '" " is 2 (l] ~ CfJ
0 '" w 1;; 0 0- n: 0> " " :. o1l
l:i -" "- l:i ~ to 0>
~ 0- -" t::. ~ o1l ~ :3 iii
0- 0> " ~ ~ 0. " " c '"
$ '!!- c c '!!- '!!- $ "l' " '" "" 0 "", - " c
"" ~ ~ E " 0 1U E '"
" 0 E " .c C< C< (l]
" 1U 0 0- W W W '" c '" V> ]i (; 0- "
"l' to i5 0 " " 2 " 0 c "E " '" CI ai
" ii5 ii5 (l] 0 ~ ~ "' ro :0 "
" c CfJ 0 ~ " '" '" c
:; Z "- " -"
c 0 0> 0> 0> '" '" - LL (l] '" ,= '" ~ 0
0 0 0 2 " " 0. C ii5
0 c c c V> V> '" V> E '" .~ CfJ C<
u: "w "e .~ .~ '" "
- ~ V> V> 2 ~ CfJ 1U ci: ci: 0>
- " 0 0 ,g ~ ~ 0 n: c 1;; c
V> 0. ,g --' " to i'! i'!
V> 0> C 1;; 1;; E "' " 'C
V> V> E c c - 1;;
'" '" '" "iii "iii "iii " " '" ~ '" c '" "- "- '"
u u ~ 0 0: 0: " " <( ,= 0 " ii" ii" '"
0 <>: C< C< f- f- 0 "- (l]
.; <'">
Z a t- '" t- oO <'">
E oo "'f "I '" "" 0 '"
'" "" " , <'"> " a <\> <9 oO "
~ 0) ~ ~ ~ ~ ~ '" ~ t- t- t-
o 0 0 0 .0 .0 .0 0 .0 .0 .0 0 0 0 0 0
a a a a :; :; :; oo co oo co oo ('oJ N N <'"> '" '"
" " " " " " " " " oo oo oo oo co oo
-
N
'0
-
~
"
"
::>
o
z
w
o
o
<(
0
0
0
0
0
ci
"'
:s "'
..
0
f-
0
0
0
0
" 0
" ci
~ "'
"'
~ ..
'c
;;J
0
0
~
~
0
~
'c
;;J
~
0
'"
,9-
t;
"
"
c
E
~
w
0
z
~
a
-'
-'
<(
</)
w
'"
;;J
f-
0
;;J
'"
f-
</)
0 'f-
00
Z :Jl;;J
E .'"
~ Of-
o</)
U>
"
"tl
..
c;,
~
"
>
w
.s
~N~
~~~
cA/1)-
oE]!
c 01 0
- " E
lllUl,[
"tl
..
o
et:
Q;
;:
i5
'"
~
..;
N
'"
of
'"
"!.
~
...
-'
<(
f-
o
f-
Ul
W
'"
;;J
f-
o
;;J
et:
f-
Ul
=
>-
'"
o
Cl
w
~
o
0 0 0 0 0 0 0 "' 0 '" v
"' 0 "' 0 0 N '" "' 0 t- V
ai tC ai N N ai <'"i cO ill oj N
N "' 0> 0 "' N 0 '" V <D N
N 0> ~ ;; "', 0> t- '" .. .. ..
",' "' ;; N .. .. cri
N .. .. ..
..
0 0 0 0 0 0 0 t- ~ "' ~
"' 0 "' 0 0 "' "' "' ~ ~ ~
oi <'"i cO N <'"i ill tC <'"i 0 0 0
N <D N 0 "' "' ~ .. .. .. ..
N <D .. ;; "' .. ;;
.. .. ..
0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0
<'"i oi tC ~ .; .; ill oi 0 0 0
N v ~ <D ~ ~ 0
~ t- N
N
(f) (f) <( <( <( Lii Lii <( u. u. u.
<( <( w w w w -' -' -'
a
(Jj
'"
u.
a
c w-
z
r=- w :::J w-
r=- uJ -' :::J
~ (f) W I1l
a </) a. > >2 -'
a >- I1l
G::' a a. a. t:. ;:: 0 >2
(f) a. w , 0 :s 0
-' ;:: a w :s
N w t9 -' I1l
~ -' -' w u. W ~
z t9 z :::J f- W I1l
~ 6 z f- W
<( z '" I a
I G::' :::J -' t:
f- (f) ~ w- w- f- a a ~ -' I
</) "' w- f- ~ Z :;; '" w ~
(f) N <( f- f- a C-
w N > 0 :::J W :J il:" il:"
a (f) '"
"'- ~ a a w a a
:;; -' -' -' eo. ... ~ " "
f- f- W W w t9 z ~ ~
(f) </) ~ ~ ~ z '" w
a a :;; 0 w w
en w ;::
a. a. z z z '" w a. a.
w w t9 t9 t9 a:' a: > </) 12 12
-' -' en en (ij a ~ <( :s f- ...
t9 t9 ~ a. a. (f) (f)
z z t9 t9 t9 '" a 0 0
(ij en z z Z f- W :;; u: u:
;:: ;:: ;:: z 0 '"
z z w a: u. u.
(f) (f) (f) :J , '" w ~ ~
t9 t9 X X X W I1l <( I
(ij (ij w w w 0 a :;; f- f- f-
~ N ~ N N v 0 0
, '" N "' t-
o J, J, J, ~ '" ,}, J, N
V 'f ,}, J, '"
'" v v v , N N
0 '" '" '" 0 0 '" '"
0 0 t- "' t- o:.
t- "- 0 0 0 0 0:.
"- "- "- "- "-
"-
N
"6
ro
Ul
Cl
z
52
et:
<(
:;
f-
Z
W
:;
W
~
a.
o
z
<(
Cl
Z
Z
Cl
en
>-
'"
o
Cl
W
f-
<(
o
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
E>
"
>
w
.s
&;N~
~~~
cAcu-
oE':
c 01 0
a;JJ~
"tl
..
o
'"
Q;
;:
i5
<D V '" 0 '" V 0 V 0 <D "' 0 0 N
'" "' 0 <D I'- '" '" ~ 0 '" '" '" N I'-
ai <'"i ill N N ill ai ~ 0 0 N cO <'"i 0
;; "' N '" I'- V '" 0 .. 0 I'- '" t- "'
'" 1'-, N '" N '" '" N <D '" ~
.. ;;; "' ci '" "' ill .. .. N' c5 ~
.. ;; .. .. .. '" ;; N
.. .. ..
:s
0
...
0 0 v 0 0 v '" N 0 0 ...~ 0 0 v
"' '" '" "' N N N "' 0 '" '" <Xl
cO cO <'"i N N <'"i .; .; 0 0 tC ill <'"i
;; ;; v '" .. .. .. v .. .. V <D V
" <D N '" ....... ;; .. <D
" N "' .. N
'i: .. .. ..
a.
~
'c
:::J
...~ ...~ 0 0 0 0 0 0 ...~ i ...~ 0 0 0
0 0 0 << 0 0 0 0 0
N ~ cO ~ <'"i tC N .; ai
~ "' 0 0 "'
~ 0) 0, v, N ~
0 .; ~ ~ ....
.
..:..
~ ..~. ...~.: :;; :;; :;; 5 :;;
'c u. u. u. '1i u. Lii Lii
;;J z z -' -' -' t9 -' z
.......
......
~ ~
0
'" (jJ
,9-
t; w
~ z
" ~ ~ :J ..~
" (jJ
c w- il:" ~ w ~
0 N '" " 9 w (jJ
E t: -' ~ ~ ~ ~ ~ ;Z :::J t9 $: a
~ I -' <f) < Cl ;Jj
w a a a a a 0 :J
~ C- o ~
:J :J :J :J :J <:2 " <f) '" 0
w- w- 0 0 0 0 0 0 - w '" ~
, 6 "'-
(f) (f) ~ ~ ~ ~ ~ ~ t!- ~
0 0 w- w- w- w- w- w- w- I w- w- 0
z z t: t: ... t: t: ... t: t: ... -'
c 0 I I I I I I I I I -'
z z ~ ~ ~ ~ ~ ~ ~ ~ ~ w
:s :s c-
<f) g a a a a a a a a a a
= ... ... ... ... ... ... ... ... ... ...
... ... ~ ~ ~ ~ ~ ~ ~ ~ ~ ~
z z 0 0 0 0 0 0 f 0 0 0 0
<( g: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;:: ;::
a. (f) (f) (f) (f) (f) <f) ~ (f) (f) (f) (f)
w w :s :s :s :s :s :s :s < :s :s :s
> > g
;:: ;:: a. a. a. a. tl. a. a. a. a. a.
0 0 0 0 0 0 0 0 0 0 0 0
w w :;; :;; :;; :;; :;; :;; :;; :;; :;; :;;
-' -' a: '" a: a: '" a: '" '" '" '"
u. u. w w w w w w w w w w
w W I I I I I I I I I I
et: '" ... ... ... ... ... ... ... ... ... ...
ci 0) 0 0 '" N ro ~ ~ ~ '"i 0
~ ~ N ~ 'f
z N '" '"' '"' ,}, .;, .;, '7 <\> "? '7 ro
E '" '" '7 '7 '7 '7 '7 ~ ~ ~ '7
~ 0:. 0:. ~ ~ ~ 0:. 0:. 0:. 0:. 0:. ~
0:. 0:. 0:. 0:. 0:. 0:.
I'-
N
"6
m
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
E>
"
>
w
.s
&;N~
N~"
'" ~ "
d,Q)-
oS':
C 01 0
a;JJ~
"tl
..
o
ct:
Q;
;:
i5
..,. '" 0
<Xl '" 0
ai cO 0
N 0, 0
<Xl 0
ill ~ "'
.. ;; ;;
:s
0
...
a> ..,. 0
a> N 0
0 <'"i 0
.. .. 0
" 0
" ""
'i: ;;
a.
~
'c
;;J
0 0
0 0
oj ro
~ 0
a> "'
0 <D ri
~
'c u. u.
;;J -' -'
~
,9
C. w
'i: 0
u Z
" <(
" '" $:
c ~
~ 0
E 0 0 -'
~ -'
:J :J <C
0 0 (f)
~ ~ t9
~ ~ z
"
0 0 '"
-' -' <C
-' -' :;;
w w
c- c- ...
0 0 z
w
... ... :;;
~ ~ w
0 0 >
<(
;:: ;:: a.
<f) <f) c
:s :s z
a. a. <C
0 0 t9
:;; :;; z
'" '" z
w w t9
I I
... ... (ij
ro :;;
ci ro a.
~ <f)
Z J, J, '"
E '7 '7 "'
~ ~ 0)
0:. 0:. 0
0
co
o
..;
o
~
.;
~
N
...
....
~
0
...
<f)
Cl
z
52
ct:
<(
:;
...
Z
W
:;
W
~ Z
0
a. ~
'"
Cl :J
z <(
Z z
Cl Cl
en en
I
- ~
~ >-
ct:
0 0
Cl Cl
w w
... ...
<( <(
0 0
N '" 0 "- <D ; N C; <Xl
0) I'- <Xl "' 0 "' "'
<'"i ai ai <'"i <'"i <'"i <'"i ai
N I'- "' "' <0 E ..,. N <0
"' "' 0) "' 0 <0 ..,. ..,.
<D cri .. ri '" ri r-: "'
.. N "- .. ;; N N
.. .. .. ..
0; <0 a> N 0) i <Xl "' ..,.
I'- "' <0 "' '" '" "-
cO 0 ai <'"i .; 0 ;; N
;; N .. .. ;; ~ a>
.. N
'" ..
..
.....
0 ii 0 .1 0 l 0 0 i~
0 0 0 0 0
0 0 0 .; ro ......
~ 0 N
~ <0
c5
N ..
.
. .... :....
.'.
u. u. u. u. u. . AS 0:: u. <(
-' -' -' -' -' -' W
..
..
..:
..
..
0 0 W- x
r=- 0
(0 Z Z Z 0 0
:::J :::J :::J :;; '"
Z 0 0 0 -' -'
<C N a: a: :;; t9 -'
I t9 ;;J
... t9 w <f) eo.
V w a: t9 t5
(f) 0 > W
(f) 0 0 0 :::J ;;;;
W ... I1l Z 12 ~
-' (0 "'- 2- '" ~
<i <i tl. (f)
9- 9- ;;;; ;;;; ;;;; 0 W
"' ~
W W ~ ~ ~ J,
a: a: <f) (f) (f) ;;;; ;;;; N '"
0 0 -' -' -' ~ ~ ;;;; z
<C <C <C 0
'" I1l Z Z Z -' -' ~ ;::
-' -' t9 t9 t9 <C <C
<C <C z z ... 0
Z Z (ij en (ij t9 t9 tl. Z
0 0 >-' to to (ij (ij 0 :::J
;:: ;:: :; '" ,
:::J ;;J uJ uJ '"
0 0 0 0 0 -' -' u: -'
w w z z z '" '" I1l -'
a: a: 0 0 0 <C <C <C :::J
0 0 0 0 0 0 0 0 tl.
'"i ~ N "' ~ '"i ~
. ~ ~- ~ J, '"' ~ ~
~ ~ . N .
.;, .;, ~ ~ N N ~ ~
"' "' '" '" '" "' "' N ,},
"' "' '" '" "' <0 <0 '" "'
<0 <0 <0 <0 <0
....
N
o
a
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
C,
~
"
>
w
.s
~N~
~C~
<ACU-
oS':
c 01 0
- " E
I1lUl,[
"tl
..
o
ct:
Q;
;:
i5
<0 <0 N N N 0 <Xl N 0 <0 0 0 0 <0
a> "' '" ~ ~ 0 a> I'- <0 a> 0 0 0 "'
ill N cO <'"i ai ill ai ai N ill 0 0 0 <'"i
..,. <Xl <0 0 <Xl <0 0 0 '" <Xl .. .. .. <Xl
..,. I'- N ..,. <0 ..,. 0 '" a> ~ a>
"' N' N N N cri c5 ..,.' ..,.' '" c5
N .. .. .. "' "' 0 '" ..,. <0 ;;
:s .. .. .. ;; .. N ..
..
0
...
<Xl ..,. N <Xl <0 0 <0 N N N 0 0 0 <0
<Xl <0 ~ I'- "' 0 <0 I'- "' N 0 0 0 ..,.
cO cO ;; 0 ::J: <'"i ill ai <0 oi 0 0 0 <0
0 a> 0 '" '" 0 '" N .. .. .. <Xl
" <0 <D "' '" I'- '" '" 0) 0) <0
" .. .. .. <D cri '" .; ai .. ..
'i: N N '" '" ..,.
tl. .. .. .. .. ..
~
'C
;;J
0 0 0 0 ...~ 0 0 0 l~ ..~ ] l~ ....~ 0
0 0 0 0 0 0 0 0
oj .; oi .; oj <'"i ~ <0
~ ..,. C; .:..... ~
N .:
. > ... >.
~ <C <f) <( <C L5 <C <C <C ~ ~ ~
'C u. (f) (f)
;;J w <C -' w w w w w <C <(
~
... I
z
0 f-
0 t9
z
>- w
'" -'
0 N
~
z Z ~
:::J
~ 0 w
0 a: a. !
:a t9 ~
a: 0
'i: W
u 0 Z ~ w
" 0- z 0 ;;;; "'-
" ;;;; ;;;; ;;;; ;;;;
0 2- u. ~ ~ ~
;:: ~ ~ ~ ~ ~ ;;;; Z
E a. (jJ Z ~ $:
~ 0 -' ;;;; '" iO ;:;- t9 0 ~ 0
<C 'I! <f) (f) <f)
'" ~ N .;, J, (ij w 0
w z 0 f-
a> t9 (f) 0 0 0 w "'- ~ z
!i;. ~ w ~ ~ ~ ~ 0 :;:- l :::>
;;;; -' -' ~ 0
w ~ 0 a: '" '" a: <(
;;;; 0 tl. <C <( <C <C 0 ; S!.
~ '> w w -' -' -' -' w ~ ~
'" f- t9 t9 t9 t9 a. , t ;;;;
(f) a: ~
w w w ~ ~ ~ ~ ~ f- ~
a: 0
>< (f) w 0 >- >- >- >- >- w (f)
0 '" 0 z -' -' -' -' -' (f) ~ ~ -'
a> w '> 0 a> a> a> a> a> ~ <(
z $: :;; :;; :;; :;; :;; z
0 a: 0 w w w w W -' , ~ t9
0 w 0 (f) <f) (f) (f) <f) <C (ij
;:: a. (f) w (f) (f) (f) <f) (f) z 1 ~
0 -' -' (f) <C <C <C <C <( t9 z
Z <C <C <f) :;; :;; :;; :;; :;; (ij i <C
:::J 0 0 w 12
, '" '" '" a: a: 0 ~
12 12 a: <C <C <( <C <( f-
'" f- f- f- u: (f)
-' 0 0 (f) f- f- f- f- f- u. W
-' W W W (f) (f) <f) (f) (f) ~ ~ 0
:::> -' -' a: <C <C <C ~ <C w
a. w w tl. :;; :;; :;; :;; f- a.
N ~ N '" ..,. 0) j ~ I
ci "' N ~ ~ 0 0 0 0 0) O;i 0;
'"i ~ ~ ~ ~ ~ ~
z , N , , , , ,
~ ~ m ;;; ;;; ;;; ;;; ;;; "' ~
E .;, m ~ N
'" , m m m m m '"
~ "' "' <0 ~ "'
<0 <0 ..,. ..,. ..,. ..,. ..,. "' <0
<0 <0 <0 <0 <0 "' "'
....
N
"6
~
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
c;,
;
>
w
o
~
t;N~
N~"
"l ~ "
'" ,,-
oS':
c 01 0
- " E
lllUl,[
"tl
..
o
a:
Q;
;:
i5
<Xl <Xl <Xl 0 0 0 N N <0 0 <Xl <Xl <Xl <Xl
I'- 0 0 "' 0 ..,. "' "' "' 0 0 <0 N N
.; .; ai ai 0 oi .; <'"i <0 .; .; ai cO oi
0 ..,. 0 0 .. '" I'- N <Xl "' I'- ..,. ..,. ro
<Xl ~ N ..,. ..,., "' "' '" I'- '" I'- ~
.. r-: .. N' ;; '" cri N N .; .. i. N
.. ;; "' '" .. .. I'- ..
.. .. ..
:s
0
f-
<0 <0 N N 0 0 <Xl ; <0 0 N ~ ~ N
N 0 0 N 0 <Xl "' <0 0 "' <Xl
ai cO ;; tC 0 oi <'"i <0 ai M .;
<0 0 N .. '" '" <Xl 0; ..,. 0
" N ;; <Xl ..,. "' ;; I'- I'-
U .. .. .. ai & .. ai ;;; ..
'i: .. ;;
a.
~
'c
;;J
0 .~ ~ 0 ~ 0 0 ~ 0 0 0 ~ ~ 0
0 0 0 0 0 0 0 0
M cO M .; <0 M .; .;
~ ~ ~
I
0
I
.
~ <f) <C <( Lii i'/i Lii <c I . Lii <c L5 (f) L5 L5 <c
'c
:::> <c w w w w <c w
.
.
;;;;
~
~ ;;;; w-
~ - - 0
a> .0 '" i't
'" "' ~ I
~ 6 '" ~ a:
(;; w
:;:- r=- :::;- 12 ...
~ w . i ~
~ ~ 0 ~ '" '" z
0 w - ..,. ..,. (f)
.. <f) (f) ~ :::;- 0 0 >- Z
0. N w :::;- .;, ,}, -'
'i: ~ ~ a> 0
u '" ~ 0 <c N N :;; ;::
" 0 w (f) 0 ri. ri.
" w w 0 a. w ;:: t t w ~ <c
c ~ (f) 0 <f) 0
"'- '> :;; a. (f) ~ ~ Z
E :::J W ~ ~ ~
Z tl. <c :::>
~ tl. -' z
$: w ~ :;; ;;;; ~ ... f- a: :;;
'" Z :::J Z Z W :;;
0 0 :::> ~ -'
<c z z :::J :::> -' 0
0 :::> -' ~ 0 0 0 f ~ S!.
~ ~ (f)
f- t:. w :;; :;; a:
z :::J f-
:::J ;;;; ;;;; ;;; -' :J w W f- Z
0 ~ ~ ~ "'- a> -' -' z w
:;; 0 0 0
S!. (f) (f) (f) <f) w a. tl. 0 :;;
w w w w (f) '" '" W tl.
= 12 12 12 12 (f) 0 0 ~ :::J
<f) <c <c <c <c <( ~ f- f- a
-' :J :J :J :J '" 0 0 w
<c X X X X 0 w w <f) -'
Z
t9 :::> :::> :::> :::J ... ~ f- f- 0 0
(ij <c <c <c <c 0 w w :J ;; '"
w 0 0 0 ~ f-
Z 0 0 0 ~ 0 ... z z (f) a: z
<c <( <( L5 L5 w ~ <( <c w 0
w w Q 0 0 -'
12 I I I I 12 12 w -' 0
w w 0
f- -' -' -' ;; -' -' -' f- f- ~ a: :;;
(f) <c <c <( <c ~ 0 (f) (f) w
w Z z z ~ z I w W :::J f- f-
0 I 0 0 f- Z (f)
w t9 t9 t9 t9 w w w w 0 0 >-
tl. (ij (ij (ij (ij > > a. a. <c 0 (f)
ci <0 I'- I I'- "' 0 "' I'- <0
a; 0 ~ ~ ~ O;i ~ 0 0
z 0 0 0 ;t .j. ~ ~ 0
'" ~ ~ ~ '" ,}, , , ~
E N m m m m r;- ,}, "' ~ ~ '"
~ "' "' "' "' "' N '" <0 <0 '" J:, J:, '"
<0 <0 <0 "' <0 <0 <0 <0 <0 I'- I'- I'- <0
<0 <0 <D <D <D
....
N
"6
N
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
c;,
~
"
>
w
.s
&;N~
N_"
'" ~ "
cAlU-
oS]!
C 01 0
- " E
Ill(/),[
"tl
..
o
ct:
Q;
;:
i5
<0 <D 0 0 0 0 0 0 0 0 0 0 0 0
01 '" 0 0 <D ..,. ..,. <Xl ..,. ..,. <0 ..,. ~ ..,.
0 .; 0 0 tC <0 <0 .; oj ill ro oj ro ill
<Xl <Xl .. .. '" N N N <0 N N N
<Xl, "' <Xl "' "' "' ~ "' .. ;; .. '"
~ 1'-' .. .. .. .; N .. ..
;; N .. ..
:s ..
0
...
~ ...~ 0 0 0 0 0 <0 <0 0 0 0 0 0
0 0 <Xl <Xl <0 0 0 N ~ N N N
0 0 0 0 ro .; .; M ro 0 0 00
.. .. ;J; ..,. "' "' <0 ;; ;; <0
" .. .. .. .. ;; .. ;;
" l; '.li
~
-
';:
;;J ..
0 ~m".~ g 0 0 ...~. ...~ 0 0 0 0 0
0 0 0 0 0 0 0 0
.; . ....~ ai .; oj ~ oj ai oj
~ ~
0 ......
......:11... '..
- <C '.<5 i'/i i'/i <C L5 <C <C <C L5 L5 <C <C <C
';:
;;J w w w w w w w w
I....
..
i z
;;;; 0
~ ~
:;:- z
-' :::>
I1l 0
~ :;; u.
w
0 (f) (f)
'" <f) <f) (f)
0. W
'i: '" I r=- <C "'-
u u. w
" ti z ... :;:- >-
" w
c ti: >- :;; w (f) -'
-' a>
E -' >- I tl. (f) :;;
0 a> -' :::;- 0 :;; <C >-
~ :;; -' w
a: a> <C ~ 0 ... a> '"
w w :;; 12 S!. w :;; (f)
a> i!; (f) W Z <(
'" '" :::J <C 15 w
!i;. <C I1l >- (f)
1 <f) z -' <C Z
<C ... a> (f) <C >-
... 0 0 S!. <C
L5 0 :;; 12 -'
z z w ... w >- '" ... I1l
W <C -' :;;
:;; I 12 -' a: 0 '" '" 0 '"
:~ ~ 9- '" '" ... W W
'" -' '"
<( ... <C <C 0 0 (f)
:::J , ~ Z (f) '" il:" il:" a: '" w w (f)
a w w ... a. <C
'" ~ t9 0 0 w w w w w
w w (ij w w w w -' -' c '" w
-' 12 a. a. e. e. -' -' 0 '"
0 0 0 0 w ... ~
a: <C u: -' -' -' -' a: '" -' 0
... :J u. <C <C ::'i <C ... ... ~ w Z
Z X ~ z z > z Z I ... <(
0 :::J t9 t9 0 0 0 0 w w a.
0 <C 5 ... (ij (ij :;; :;; 0 0 > 0 (f)
:;; :;; w w w w w w w w w w
w w > > > a: a: > > > > >
... ... ~ 0 0 0 w w 0 0 0 0 0
(f) (f) :;; :;; :;; -' -' :;; :;; :;; :;; :;;
>- >- w w w 0 0 w w w w w
'" '" a: a: a: tl. a. a: '" '" a: a:
ci <0 <0 i I ~ '"i ~
~ 0 i 0 0 ~ , 0 '" 0 0 0
z ~ N '" '" '" "' <0 I'- <Xl
~ ~ '" '" '" '" '" '" "' '" '" '"
E '" ,}, '" '" '"
<Xl <Xl 0) 0) 0) 0) '" 0) 0)
~ "' <0 <0 <0 <0 '" 0) <0 0) <0 <0 <0
<0 <0 <0
....
N
o
ro
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
c;,
~
"
>
w
.s
&;N~
N_"
"l ~ "
....-
oS':
c 01 0
- " E
Ill(/),[
."
..
o
ct:
Q;
;:
i5
a a N N ..,. <Xl <Xl N a
..,. ..,. a I'- N 0) a 0) a
.; .; M cO M tC <0 0 0
'" '" '" "' <0 <Xl I'- <D a
I'- I'- '" ..,. <0 0), I'- <Xl a
.. .. 1'-' "" c5 ;; ai "' "'
'" .... '" .. .. '"
.. .. .. ..
:s
0
...
a a <0 ..,. ..,. <Xl N ..,. 0
<Xl <Xl a N N 0> a <Xl a
~ ~ <0 cO 00 tC .; 0 0
0> "' <0 <Xl 0> "' a
" N N ~ ~ <0 0> ~ ;J; a
u .. .. '" "' ci ;; N "'
'i: .. N '" .. '"
tl. .. .. ..
~
';:
;;J
a a l..~ l..~ a a '.~. ...~ a
a a a a <<
M M ~ ~ I. ~
~ . .....
...
. :.H ..
i .... ....ir ......
- <C <C <( (f) (f) '" (f) <C
';:
;;J w w w <C <C <C <C w
~
0
'"
0.
'i:
u ... r=-
" Z
" W Z
C :;; r=- :::J
E '" Z 0
~ :::J :::J :;;
0
a :;; 0
w <C
-' 0 w
t9 <C W- Z I
Z Z :;; :::> '"
:J t9 <C a: a: 0 w (f)
(ij w w a: > w
'" Z > > S'!. Q. 0
<C (f) ... w w V Z
0 :::J ~ -' -' z z <(
0 ;:: ;:: a:
0 :;; 0 0 0 $:
z w Z Z 0 0
<C Z :::J <C <C L5 L5 "' 0
:s -' 0 0 -'
... =' - -'
:; 0 0 '" '" <C
-' -' <C <C ;;;
0 w <C t9 t9 z
z 0 w w Z Z ~ 0
'" Z I I
0 a: '" a: I I -' ~
0 ~ w w w (f) (f) w
w w ... > > :s :s z
> > ~ 0 0 <C :J
0 0 u. U. tl. <C
:;; :;; z z z z Z z z
w w t9 t9 t9 Cl t9 t9 t9
a: '" (ij (ij (ij (ij (ij (ij (ij
~ N N <Xl
ci a 0 ~ ~ ~ ~ ' -'
a , ~ ~ '" , J:, 2<c
z 0> ~ ~ N "' 0
'" m 0> 0> ..,. o>Z
E 0> '" '" N '" '" '" 't9
~ '" 0> '" '" 0_
<0 "' <0 a a a a 0 O(f)
I'- I'- I'- I'- I'-
~
I'-
.,;
..
<0
C
I'-
"i
~
...
"' a <0
a "' '"
0; .; 0
'" I'-
'" '" <Xl
<D ai ",'
'" '" ;;
.. ..
I'- "' <Xl
I'- "' ~
0 oj .,;
.. .. '"
..,.
<D
..
a a a
a a a
0 0 oj
I'- 0>
"' 0>
r-: .;
..,. ~
u. u. <C
-' -' w
t9 0-
z ..,.
;:: I W-
I 0
t9 (f) t9
:J 0 ~
"' > -'
e:- O
c:i 0 >
~ >-
Z '"
0 :::J <C
w 0 0
~ a: z
t9 0
:::> a: 0
(f) w w
Z 0 ~
Z
:::> ;;;;
;;;; ~
~ ;;;;
~ '"
'" w
0 t: ...
... :::J Z
0 0 W
:::J Z 0
C 0 0
Z 0 <(
0 0
0 N -'
'" ~
~ ~ ~
~ N ~
,}, ,}, .;,
0:. 0:. 0:.
....
N
o
;;
-'
<C
...
0
I-
Z
0
~ Cl
:J
<C z
z ;::
Cl I
en Cl
::;
~ :>
~ >-
ct:
0 0
Cl Cl
w w
... ~
<(
0 0
~
"
"
::>
o
z
w
o
o
<(
U>
"
."
..
c;,
~
~
w
.s
~N~
~C~
c:AlU-
oE':
C 01 0
- " E
Ill(/),[
"tl
..
o
a:
Q;
;:
i5
"' 0 0
<Xl ..,. 0
oj cO 0
N ~ 0
~ ~ 0
cri <D c5
.. 0) ;J;
~
:s ..
0
f-
<0 0 0
~ '" 0
oj ro 0
N 0
" '" 0
U .. '" c5
'i: .. ;1
"-
-
';:
;;J
0 0 0
0 0 0
00 ai ~
~ ..,. "'
0
-
';: L5 L5
;;J
;::-
I
t9
W
I
Cl
Z
;::
Z
:::J
0
:;;
0
:!-
Z
t9
en
w
c
c:: -'
0 <c
'" 0
0.
"5 w
a.
" '"
" ~
c
E :::J
G" z
~ z ~
;:: :::J-
-,f-
I <cZ
t9 -:::J
2- "'"0
W- [i!:;;
-a:
c Ww
'" f-o
0 w-'
<c -':::J w
0 tl.O 0
g2 :;;I z
O(f) ~
;;; 0:;;
~ ~a: 0
-'
(f) o<c -'
W tl.N <c
>< t9~ t9
0 ZW z
'" - -' ;::
-' f-t9
-' Iz I
:::J Cl- t9
tl. -(f) :J
-' -
0
ci ~ ..,. 0'"
~ ~
z .j. ,
~ "'I
E ~ "' "it9
,}, 0-
~ 0:. ob 0-'
0:.
>
>-
ct:
o
Cl
w
~
o
0 "' "' 0 ..,. .. "' ..,. <Xl 0
0 "! 0 N "' "' 0 0> "' '"
0 ~ oi .; 00 oi <0 0 oj oj
<Xl 0; '" <0 ..,. 0> I'- <Xl <0 "'
<0 0, "' 0> 0> "' ..,. <0
- "j .. <D .; .. ri .; .. r-:
0> ;; 0> '" .. ;;;; ..
.. '" ..
..
0 "' 0) N N I'- N N <Xl 0
0 N 0 ..,. I'- '" "' I'-
i. 0 00 <0 oj oi cO "' N .;
N N N I'- 0> 0:. <0 '"
.. .. .. ..,. ..,. '" <0 <Xl
.. .. .. .. .. ..
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 << 0
0 cO cO 0 .; oj cO tC ~ oi
I'- ..,. ..,. C; I'- ~
~
<'i "'
N ~
U. U. U. u. <c <c <c u. <c L5
-' -' -' -' W W W -' W
~ ~
(ij en
tl. tl.
0 0
"' "'
~ ~
W- W-
f- f-
<( <c
~ ~
g g
;;; ;;;;
~ ~
;- (jJ (jJ
;-- ;- ;- W W
0> 0) a. a.
0> 0> oi oi ~ ~
.; tC ~ b> ~
ai , ;- -' -'
-' -'
0 0 0 ~ 0 0> <c <c
?1 :5 ~ , ~ ai
0 '" '"
~ '" a:
a: '" a: ~ ~ w W
w W w W 0 > >
$: $: $: ~ ;- 0 * 0 0
w W W 0 N :::> 0 0
(f) (f) (f) '" !5 0 W W- W-
i;: i;: i;: -' w W (f) (f)
W W W ~ <c g2 ~ <c <c
f- i f- 0 W W
<c <( Q W Q Q -' -'
Ul ~ ~ tl. W W
w ?'O g ~ g ~ '" '"
;:: 0 0 0 a: a:
:J > > > ;;;; '" ;;;; '" ~ ~
i= ~ a. ~ ~ ~ ~ ~
2:' >- >-
::J :::;- (f) (f) (f) (f) -' -'
, '" '" '" t9 t9 t9 t9 '" '"
:> ::'i ~ ill ill z z z z :;; :;;
w ~ ~ ~ ~ W W
>- 0 a. a. a. (f) (f)
ct: :;; 0:: 0:: 0:: u: u: u: u: (f) '"
0 W ~ ~ ~ >- ~ ~ >- <c <c
" ~ f- f- W W
W W :J :J :J :J :J :J :J ~ >
~ a. ;:: ;:: ;:: ;:: ;:: ;:: ;:: -'
0 0:: :::J :::> :::> :::J :::J :::J :::J ::'i ::'i
N '" ..,. ..,. ..,. .. ..,. ,
N N N l' 0> '" N
~ '"i '"i '"i "i 'f 'f ~
~ ~
'" ~ ~ ~ ~ ~ ~ ~ ~I'- ~ '"
N ~ ~ ~ ~ ~ ' 0 ' 0
0 '" '" '" , .;, ob , RN RN
"' "'
~ "' "' "' "' "' "' "' 0 0
0 0 0 0 0 0 0 ~ ~
~ ~ ~ ~ ~ ~ ~
....
N
"6
~
..
~
..,.
N
.....
N
...
...
...
..J
<l
f-
o
f-
Cl
z
i=
I
Cl
:J
~
"
"
::>
o
z
w
o
o
<(
U>
"
"tl
..
c;,
~
"
>
w
.s
... -ci
",Net:
N_"
'9;.!!
~E~
c 01 0
- " E
Ill(/),[
."
..
o
a:
Q;
;:
i5
..,. <0 <0 ..,. <0 0 0> N "' 0 "' I'- <Xl N
~ I'- "' <0 <0 "' N <0 <Xl "' "' 0 <Xl
"' cO <0 r--: N tC ~ ai 00 a; 0 0 ai .;
~ 0 0> "' 0 0 "' "' "' 0> <Xl 0
~ N "' '" ~ 0> I'- ..,. <Xl ~ '" <0 N
N <D .; '" N N' N <D .; <0' c5 c5 "' <0'
.. .. ;; ;; .. .. .. ;; N .. '" '" .. ~
.. .. ..
:s
0
f-
I'- ..,. N N '" "' 0> '" '" <0 ~ '" C; N
"' 0> '" <Xl '" I'- N 0 I'- '" ~ I'- '"
0 00 M ai <0 00 ~ "J, 0 ai 0 <0 ~ .;
'" "' ro, 0) I'- "' C; 0> I'- '" I'- 0:. 0
" 0, "', <0 0_ ..,.- '" <Xl <<>, 0 '" N
,!,! <D N N .; <0' '" .. <D
ti. ;; ;; ;; .. ;; ;; .. .. .. ;; .. .. N
..
-
';:
;;J
0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0
oj .; ai oj oj oj ~ tC cO cO cO oi ai ~
~
0
~ L5 L5 L5 L5 <C <C <C <C <C L5 L5 L5 L5 <C
';:
;;J W W W W W W
~ 0 N- oo ~ ~ 0 N (0
~ ~ ~ ~ ~ ~
(ij (ij (ij (ij (ij (ij en (ij (ij W w
a. a. tl. tl. a. tl. a. tl. tl. (f) <f)
0 0 0 0 0 0 0 0 0 <C L5
"' "' "' "' "' "' "' "' "' W
~ ~ ~ ~ ~ ~ ~ ~ ~ -' -'
W- W- W- W- G" G" G" G" G" w w
a: a:
~ ~ ~ i ;;J :::> :::> :::J :::> a: a:
-' -' -' -' -'
~ ~ ~ ~ "'- ~ ~ ~ ~ ~
~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ N
~
;;; ;;; ;;;; ;;; ;;; ;;;; ;;;; ;;;; ;;; ;;; ;;; ~
~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ W
~ (jJ (jJ (jJ (jJ (jJ (jJ (jJ (jJ (jJ (jJ (jJ tl.
0 ::;;
'" W W W W W W W W W W W :::J
.9- tl. tl. a. a. a. a. a. a. tl. tl. tl. ll.
~ ~ ~ >- ~ ~ ~ ~ ~ >- ~
t; ... ... ~ >-
" -' -' -' -' -' -' -' -' -' -' -' W -'
" -' -' -' -' -' -' -' -' -' -' -' '"
c <C <C <C <C <C <C <C <C <C <C <C (f) :;;
0
E '" (f) '" (f) (f) (f) (f) '" (f) (f) '" I W
~ '" '" a: a: a: a: a: a: a: '" a: '"
w w w w w w w w w w w ~ (f)
> > > > > 6 > > > > > 0 <C
0 0 0 0 0 0 0 0 0 0 ... >- '"
0 0 0 0 0 0 0 0 0 0 0 0
ur ur ur ur ur ur ur ur ur ur ur ~ -' W
'"
(f) (f) (f) (f) (f) (f) (f) (f) '" '" (f) ;;;; :;; I
<C L5 L5 <C <C <C <C <C L5 L5 L5 ~ w 0
w w w w w w <f) a:
-' -' -' -' -' -' -' -' -' -' -' >- (f) 0
W W W W W W W W W W W -' <C ...
a: a: '" '" '" '" 0:: a: a: a:~ a:~ '" 0
"';... ~t!. ::;; a.
'" '" a: a: a: a: '" a: '" ~ W
;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; ;;;; %5f :'f5j w ...
'" W
>- >- >- >- >- >- >- ~ >- ~a. ~a. (f) w 0
-' -' -' -' -' -' -' -' <C -'
'" '" '" '" '" '" '" '" '" ",0 ",0 ... a. :;;
:;; :;; :;; :;; :;; :;; :;; :;; :;; :;;"' :;;"' z :;; w
w w w w w w w w w W~ W~ ~ <C ...
(f) (f) '" (f) (f) '" (f) (f) (f) (f):;:- (f):;:- (f) (f)
(f) (f) (f) (f) (f) '" '" (f) (f) (f)-, "'-' 0 a. >-
<( <C <C <C <C <C <C <C <C <C'" <C'" >- :;; (f)
W W W W W W W W w W:;; W:;; I W W
> > ::'i ::'i > ::'i ::'i ::'i ::'i >W >W w ... '"
-' -' -' -,(f) -,(f) a: t! u:
::'i ::'i ::'i ::'i ::'i ::'i ::'i ::'i ::'i <C(f) <C(f)
><C ><C u: ~ oo
N "'
, , , .j. .j. .j. .j. .j. 0 0 ~
ci ~ ~ N '"i ~
~ ~ ~ ~ ~ ~ ~ ~ ~ ro ,
z '" '"
~'" ~o ~ ~ ~.,. ~ <Xl ~O> ~O ~ ~ ~'" ~ ~ ~
, 0 ON ON ON ' 0 ' 0 ON ON ON
E RN RN RN ~
~ I'- I'- I'- I'- I'- I'- '" '" .j.
0 0 0 0 0 0 0 0 0 I'- I'- ..,.
~ ~ ~ ~ ~ ~ ~ ~ ~ 0 0 <0
~ ~ ~
....
N
o
~
~
"
"
::>
o
z
w
o
o
<(
'" 0
0 0
ill 0
'" 0
~ 0
c5 c5
N 0
:s .. N
..
0
f-
0> 0
0 0
<0 0
'" 0
" ~ 0
U c5 0
'i: N 0
tl. .. N
- ..
Oc
;;J
0 0
<< 0
~ ~
~
0
~ <C
'c
;;J w
~
,9
C.
'i:
u
'"
"
c
E
~ >-
-'
'"
:;;
w
'"
'"
<C
'"
w
...
w w
:;; 0
a: z
w ~
I-
~ 0
-'
w -'
-' <C
'" (f)
~ w
;::
0 :J
tl. ;::
" :::>
-'
ci ;::
:::J
Z '"
E "'
~ '"
J
0
U>
"
"tl
..
E>
"
>
w
.s
t;N~
~~i
cACIl-
oE~
c 01 0
- " E
lllUl,[
"tl
..
o
a:
Q;
;:
i5
...
...
..;
'"
..,.
,.:
'"
..
...
0 0 0 0
0 0 0 ....
0 0 ci 00
.. .. ... "'
N
<Xl'
'"
....
..
:!
M
N
OA
0 0 0
0 0 0
oj M cO
"' 0 0>
<Xl, 0> ..,.
~ c5 .;
<Xl '"
~
>- '" u.
0 -' '"
c
"
~
ro
E
Q;
eo.
-'" -'" e-
rn rn Ul ,Q
$: $: w 1ii
Ol Ol et: -c
~ :::> ~
'c c f- ~
'c 0
'0; '0; 0 u.
Qj Qj <C ;;J Ol
a: a: c
'" S I- '0
- a; ~ Ul ~
ro ~ "
'" " = 5
.. ii5 S
<C 0 01 :;;: ~ III rn
.s oi c 0 .s $:
.. e1 'Q :s Cl ..
c .2 .s w ~ -c
~ u c ~ ~ ~
.s ~ .0 .s ~
0 'a; ~ 0
:;;: 0 a: Ul 0 :;;: '"
~
-'" ~ '" -'" 0
ro ~ , rn ~
" N ~ " N
-c '" ,}, -c I'-
c 0 ~ c .j.
~ ..,. ..,. ~ '"
0 0 "'
'" '"
....
N
"6
....
....
<(
...
o
...
Ul
w
i=
:J
i=
;;J
:>
~
o
Cl
w
...
<(
o
Ul
W
...
<(
Z
et:
W
f-
-'
<(
(')
'*"
::;: co C") ... N
~ ...
0 C'! ~ C") ~ CO
Z ... ... N .,; ...
W ~ ...... ~ It) It)
0 0) N 0 N N
0 ..f iii' 1 ..f al
4: co C") co ~
~ ~ ... ~ co.
t!) N ~ 0)- 0)
... ~ ... ...
~ ~ ~
~
c
<(
a
a:::
I/)
<(
w
~
D..
:i!:
<( <( VI
0 ~ Gl
-
u.. ~ ClI
a 0 I:
0 ...
I- co Gl
-
I/) 0 <C
w
s: z VI
I- ::l
a 0 a:::
......1-<( w - >
~c~ .., ..c:
It)<(- a 01 ..c:
, a I: a::: ::l 01
0) Gl
oa:::E D.. 0 ::l
... 0
c W 01 >- ..c: ...
-cGl I- - ..c:
lD~1/) Z -
~ VI
a Gl VI
C) ";:: Gl
0 0 ';::
....l a::: '" 01 0
....l E Gl 01
W W Q) - Gl
s: ::::i == ClI -
0 ClI
....l ....l >.. 0
0 t1l
a 0 0... ~
- (f) N
C C) - -
I: I:
<( Z Gl Gl
a ~ E E
a::: 0::: 01 01
....l <( Ql Ql
....l ::;;;; I/) I/)
W l- I-
s: -I- Z Z
- (/) =z ~ ~
....l ~ ~E ~w 0 0
0 o (/) 02 0::;;;; :i!: :i!:
OlE 01- ClW <( <(
.l!l Q) Ql >.. Ql>
- t1l -<( C C
ClI== ClIo... ~o... lD iii
0 >.. O(f)
_ t1l -0
1:0... 1:w I:z W W
::l>- ::l0::: 5<( I/) I/)
0<( 0::> ~ <(
Es EI- EC) lD
<(0 <(0 <(z ....l ....l
-::> -z ~ ~
ClI<( .Bo::: .BC)
-0 01- a 0
~o::: 0_
I-(f) I-(f) l- I-
0 0 0 0 0 N 0 ~ <Xl 0 N
0 0 0 0 0 '" N ~ ..,. 0 on
it 0 ci ci ci c5 <0 M .,; .0- <ri M
0 0 <Xl 0 0 on <D N "" <Xl ...,.
::;; "< 0 ~ 0 0 on '" N, ..,., 0,
:::> - ~ "' c5 ..;- <D ..,j '" '" on
0 " '" CO ~ I'- N CO
Z ::I I'- I'-
W 0 ..,j
0
0 E
'" <
0 0 0 0 0 N ..,. '" '" 0 N
0 0 0 0 0 ~ 0 ..,. on 0 ""
ci ci c5 c5 ci <ri oj 0 .; N .0-
0 0 <Xl 0 0 ~
" "', 0, ~ 0 0 ~,
U ~ "' ci ..;- '"
'i: '" <D
0.. I'-
-
'c
;;J
C
< 0 0 0 0 0 0 0 0 0
0 << 0 ~ 0 ~ ~ 0 0 0
0: ~ ~ 0; ci <ri <ri
(fl <Xl co. ~
:;;;: >- ~
w t) "'
l.:
tl.
::;;
<
0
LL -
0 'C '" '" '" '" '" u. U. LL >- >-
f- ;;J .... .... .... .... .... .... .... .... 0 0
(fl
W
;:
0
1'-....<
<XlC"" ....
~<(c: '"
a.OC1J "6
oO:E m
cw
-c"
lDi2(fl
Cl
....
.... ...
W
s: :::>
0
.... ~
Q. "
c 0 0
.,
< Co Z (f) W
0 Oi: <( f- ....
0: u t9 z :::J
" '" W
.... " Z z :2 0
.... c :) ;;: :::> w
w E w Z I
s: tl. > 0 0
" '"
.... "" F- 0: :;; 0:
0 =' :::> f- W 0: -
'" >- 0 0:
:::> w w w w t9
~ ro z > .., 0: 0: tl. Z
0 a: 0 ~ 0: t. a:
'" i= :::J 0: <C a; :)
c ~ 0 '" tl. ~ I1l ro
< :::J W :::> :::J
Z u. Z ~ 0 0: (')
0 ~ 0: 0 ~ 9 z t9 w
a: f- ro 0 w a:
(f) z 0
z z z 0 Z 0: a; LL f-
>- 0 ;;;: 0 ~ ;;;: :::J a: ~ z z z
0: ~ :2 0 :2 ... :::> <C 0 w
0 W w W a: t9 f- (jj t9 ;:: :2
Cl 0: Z 0 0 z ::'i YO
0 0 0 w 0:
w :J '> '> W '> 0: ~ w w z
... a; '" YO '" <C <C <C
<( 0 0 W 0 0: 0 ~ ~ W 0 I1l
0 0 0: 0: a: a: <( ...J -' >< :;;
:;; a.. a.. tl. a. I1l LL (f) '" 0 W W
0 ~ '"i '? ~ ~ N ~ ~
Z ~ , '"i I'- ~ ~ ,)-, ""- ~ <0
~ ~ ~ 0 0
C; , , , c; , , -+ ~
E ~ ~ ~ N ..,. -+ 0 N N
~ ~ 0 0 0 0 0 0 ~
~ ~ ~ ~ ~ 0 ~
~ ~
0 CO ..,. N ..,. <Xl I"- ~ ..,. "' N '" ~ 0 "'
<Xl '" ..,. I"- ..,. ..,. (") I'- 0 CO CO CO '" ":
11 cO <Xl cO .0 cO <Xl N c:i c:i cO cO .0 cO cO ~
"' ~ co I'- 0 I"- CO 0 '" '" '" <Xl CO CO "'
" I'- '" CO N '" ~ N CO <Xl OC CO, CO "'- '"
OJ - ..f ci <D ..f .0 '" '" ..f '" N ~ <0 .0 ~ ai
0 r:: I'- I'- CO N <0 CO N N, CO ..,. ~ N N
Z ::l N ..,. ~ ..,., 0. 1'-, ~
LU 0 ~
0
0 E
<( <(
'" CO <0 <Xl N 0 ..,. CO 0 I'- ..,. ..,. ~ CO CO
CO 0 '" <D ~ 0 '" I'- <0 I'- ~ N CO ~ (")
cO N cO cO ....: .0 cO .0 tC <'"i M oi .0 r-: c5
CO CO N N '"
" CO '" (") <D, I"-
u N ri
't: N
"-
-
'C
;;J
0
<( 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 C> 0 0
D:: r-: oi oi r-: c:i cO oi cO .0 cO ~ -<i .0
Ul <Xl I'- I'- CO CO '" <Xl CO ~ ~ ~ CO
<( ~ ..,. <0 <0 I'- I'- '" <0 I'- ~
W oi ..f ri .0 ci '" ci c5 '"
>:: 0 N N 0 ~ ~ '"
N N N N N
"-
:;;
<(
0
LL -
0 .C u. >- >- >- >- >- >- >- >- >- >- >- <( <( L'i'i
f- ;;J '" '" (/) (/) '" (/) '" (/) '" '" 0 0 W W
Ul
W
;:
0
I'-f-<(
~C"lt ....
"'<(-
cAO; N
"6
OD::E ro <q 0
cw ~ ~ :::;- N
-Cal
Ill~Ul '" N -'
N N ~
Cl cD cD
.... I'- I"- ~
.... ro 19 t9
w ~ eo. e:- '>
~ 0 G 0 ~
.... t9
Q. ~ 0 () 0 a:
c 0 '" u: u: u: '" a
'" w U. LL LL N ~
<( 0. tl. <C <<: ~ cD
0 'i: 0 cr: cr: I'- (jJ
D:: u .... l::- t:. t:. 19 ...J
"
.... " (/) e:- ...J
w W w ~
.... c o! ;:;- 0- ~ f- f- ... iO
w E a 0 ~ ~ w w w
~ ~ (/) tl. tl. a. cr: cr: cr: 0 (jJ t9
.... ::J ::J :::J 0 0 0 "=- -' z
C -'
5 w a a 0 z z z <C z
0 cr: cr: a:: a 0 a iO $: ~
a:: t9 t9 t9 0 () 0 N 0 0- 0- 0-
a 0 () 0 ~
w w w 0 f- Z w ~
LL co (/) '" '" i= ~ ~ z !!:!- ~ ::!... ::!... ::!...
z w <C <<: <C -' ~ w
W tl. '" '" '" <<: <C <<: w :;; w w iO iO ii!
a:: ~ I I I W ... f- e'o. e'o.
tl. tl. tl. '" ::c w w 3
() .... .... .... (/) (/) (/) a: a: cr:
i= z <( <<: <C <C <<: <C ::J tl. 0 0 iD iD iD
a z z z 0
w 0 0 0 w w w z z a:: a: a:
I ;:: > > > 0 I 0 0 :::J :::J :::J
f- ;:5 ;:: i= i= <<: <C <C z tl. 0 0 S S S!.
Z tl. tl. tl. tl. a. tl. 0 '"
>- :::i 0 a a a:: a: cr: i= <C '" '" (/) (/) '"
'" I1l W W W W W w <5 '" '" f- ... ...
a ;': '" (/) '" a. tl. tl. 0 :'5 :'5 w w w
w <C <<: <C :::J ::J ::J oc '!2 -' ...J -'
t9 '" I1l I1l IXl (/) '" '" u. :;; 0 0 ~ ~ ~
ci ..,. 0 ~ ..,. (") ..,. 0) ~ u:; ~ ~
'"i <0 CO
Z ~ ..,. 0 0:. ~ N N N ~ ~ '7 '" 'f
.0 0 I'- I'- , , , rC. m ~ , ,
, ,}, ,}, ~ ~ ~ '" ~ ~ ~ ~
E ..,. co "' -+ .j. .j. '"' (") 0 , .0 .0
~ ~ '" co <Xl '" (") '" '" '" 0) 0 co
N N N '" (") '" '" ..,. ..,. N N N
..,. ..,. ..,.
co 0 ..,. <0 0 '" "' CO 0 I'- 0 co <Xl <0 .....
0 <Xl ~ <Xl '" N '" "' ~ <Xl CO ..,. '" ~
it on ci ~ on ci M M M i, oi M M cD ci on
..,. co co "'- <Xl 0 '" '" '" 0 ~ CO CO
::;; I'- CO ~ '" '" '" ~ CO "', N ..,., ..,.,
:::> - '" N .; r-: 00 cri r-: N ori co ori <Xl ..,.
0 c: CO N <Xl N "' <Xl I'- ..,.
Z ::l ~ N
W 0
0
0 E
<( <(
I'- 0 ..,. CO 0 I'- '" <0 N 0:. "' CO ..,. ~ ~
CO ..,. ~ CO '" "" ..,. N <Xl 0 <Xl N 0
oi cO ~ on ci ;;; o:i .; oi r-: on ~ M ci on
..,. "' ..,. <Xl "', ~ N N '" <D I'- N '"
" N N, ~ CO ~ ~ ~
0 ..; .; 1'-' '" <Xl
'i:
D..
-
'c
::>
C
<( 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 << C! << 0 << 0 0 0 0 0 0 0 0
0:: on oj ~ oi ~ M r--: r-: M cD M r--: M
'" ~ I'- co '" co 0 I'- <0 '"
< ~ N 1'-, N <Xl CO "'- 0.
w ori ~ N N N N
lI:: (J
tl.
:;;
<(
0
LL -
0 'C <( lii <C lii <( <5 <C u. LL LL LL U. lL U. u.
f- :::J W W W W -' -' -' -' .... .... .... ....
en
w
3::
0
""'f-<(
reC'l:t ....
In<(1: N
rA 0 Q) -
0
00:: E ~
cw N
-C"
lll~en
t9
.... ~
.... Co " 0 <0 N Co ;,. b
w S ~ ~ ~ ~ ~ ~ ~
3:: ::J ::J ::J ::J ::J ::J ::J ::J
.... <C <C <( <C ~ <C <( <C
~ c: 8 ~ ~ ~ ~ a: ~ ~ 12
0 8 ~ w w w w w w w w
c '" ~ !;;: !;;: !;;: !;;: !;;: !;;: !;;: ...
<( 0. I. <C
0 'i: :;; :;; :;; :;; :;; :;; :;; :;;
0:: u 8 0 .... -' .... .... -' -' -' -'
"
.... " I. 0 0 <( <( <C <C <( <C <( <(
.... 0 0 :;; z z z z z z z z
w E :;; 0 0 0 0 0 0 0 0
3:: " 0 W :r: ;:: ;:: i= ;:: i= ;:: i= ;::
.... :!:: W W W tl. a. tl. tl. tl. a. "-- tl.
(5 a. tl. tl. ~ ~ Q. ~ Q. ~ Q. Q.
8 ~ ~ ~ > > > > ~ ~ > >
.... .... .... .... -' ....
:::J :::J :J :::J :::J :::J :::J :J
::!..- :;; :;; :;; 8 8 8 0 0 0 0 0 0 0 0
0 0 0 ~ ~ ~ 0:: a: 0: a: 0: a: 0: 0:
<0 t::: t::: t::: ::!..- ::!..- ~ w w w w w w w w
, $: S $: $: $: S S S
::2- 0 0 0 &3' &3' "I
I1l OJ OJ W W W W W W W w
1ii' ~ , '" '" en '" '" '" en '"
a: :r: :r: :r: ::2- ::2- :;; :;; :;; :;; :;; :;; :;; :;;
:J 0 0 0 '" '" '" a: a: 0: 0: 0: a: 0: 0:
S!- f- ... ... w w w 0 0 0 0 0 0 0 0
9- 9- 9- -' -' -'
en 0 0 0 ... ... f- ... ... ... ... ...
f- f- f- f- I I :r: '" '" '" '" '" '" '" '"
W W W W Z Z Z w W W W W W W W
-' -' .... -' <( <( <C tl. tl. tl. "-- a. a. a. "--
~ ~ ~ ~ :;; :;; :;; 0: a. tl. tl. 0: 0: 0: a.
~ ~ '" N "' '" '" <Xl 0 :r N '"
0 ~ ~ N 'i' '"i '" '7 'f ..,. 1"
co N "' <Xl <0 '" '" , ,
z 1" '" "' '" N N , 0:. ~ ;::: 0:. ;::: ~ ~ 0:.
, N I'- I'- I'-
E , , ~ ~ .r, .r, .r, ~ ~ ~ ~ ~ ~
, ,},
" CO "' "' N N N '" '" '" '" '" '" '" '"
:!:: N N N N
..,. ..,. ..,. ..,. ..,. " ..,. '" '" '" '" '" '" '" '"
..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,.
..,. ..,. 0 0 ~ 0 I'- N "' N 0 CD <Xl on
N oq C! '" 0> '" '" on ..,. ~ 0 0> N '"
;t M N <Xl .0 oj a to a oi oi to oj .0 .;
0 on .... ~ .... "' '" .... ~ '" .... 0> N ....
::;; on '" ..,., <Xl on 0 N, .... ~ N <Xl <Xl <Xl
:::J - o:i o:i ~ '" N '" ~ .... 0 .0 .0 cri N '"
0 ~ '" ~ '" ..,. 0> ..,.
Z " '"
w 0
0
0 E
<( <(
~ <Xl 0 '" ~ on N '" N I'- 0 ..,. ..,. ....
on <0 0 I'- <Xl <0 ~ on ..,. '" 0 N N ~
a .; to .0 .0 r--: ~ oi oi .; N oi oi to
~ CD N N N N on ..,. '"
" '"
u
"i:
"-
-
'2
:::J
6"
<( 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 C! 0 0 0 0
l>: .; <'"i M a to r-: ~ ~ .0 M to
Ul N ~ 0;, ~ 0 0 ~ ~ ~ on
<( >- "', N 1'-, "', '" '" N ~ oq
W f- ~ ri <Xl
" CJ
tl.
::;;
<(
0
lL -
0 .c u. u. u. u. u. U. lL U. >- >- >- z u.
f- :::J .... .... .... -' .... .... -' -' '" '" (f) f- -'
'"
w
3:
0
I'-f-<(
<Xlc.... I'-
~<("E N
cAoc>> '0
Ol>:E N
Cw N
-c"
lllQ!!Ul
t9
.... ~
.... N w-
w t::- o
3: ::J" :"i
.... <(
2- 0:: "--
~ z
0 w W
c '" ~ f-
<( a. 0 Ul
0 'i: :;, ~ @. :;: <C
l>: u .... S!- Q"
" <C 0 0 ::J" ~ ....
.... " w
.... c z w w w G::' -' ~ I>:
W 0 '" '" w ~ -'
3: E <C <( ... <( o~
;:: w $: w Xo
~ tl. 0 0 ~ tl. W 0
.... z z ~ tl. "'-
0 Q. w w ::J" ~ I>: ~ oa:
w Q" Q" zl1l
> f- f- ~ 0 0 0:: -' <C~
-' 0 0 ~ 0 ~
:::J 6 6 z w U I>: I "a: :;:-
w 0 z <( I ::J"
u a. l- f- :::J Zw <(
0 0 ~ 0 I1l ~
I>: 0- 0- 0 ... <Cf- $:
w ..,. ..,. :::J I>: W ~ @. 0 11l=' 0 0
s 0 0 8 w I1l I>: t;j w ~u. <( :;,
w w ~ I>: 0 0 0 !:: ~o w
W I I -' :::J ~ a: z z x z 0 w
(f) <( :::J 0 0 0 I1lW !:S !:S
0 0 0 z 0 11lt9 0
:;, I>: t9 I>: 0 0 I>: f-
~ ~ 0 :::J", -' ....
I>: 0 0 OJ <C '" " <C '" <( ~
... tl. 0 !:Sw
0 0 0 z z W w -' -' ui t9 I>:
f- > > <C <C a: '" z ~ ~ I>: tl.o Z 0 0
'" "-- tl. X <( ~3
'" 0 lL 15 w 15 I>: I>:
w W w W I>: Z <( W W > ,,--0 0 <C <(
'" eo tl. tl. :::J 0 a: W 0 0 <( -z W :::J :::J
"-- a. a. "-- 0 0 f- :;; U5 U5 tl. 1>:= co (') t9
on '" <0
0 --r 0; 0; ~ 0 ..,. ~ '"i '" ..,. ~
~ N '"
Z ~ , , N ~ ~ N .... , I'-
<0 ~ ~ ,;, , N N ~ ~
.... <0 ,;, ~ 6 ~ <.b 6 '" <.b ,
E ~ '" '" 6 6 N N N <0
" 6 6 6 N N N "' on "' N '" '" '" '"
on on on "' "' on on
'" '" '" '" on on
..,. ..,. ..,.
0 0 (0 0 0 '" 0 0 ~ 0 0 ..,.
'" 0 '" '" N 0 <'! <'! <Xl .....
11 cO ,.-: ..; 0 N N 0 ~ ~ <D <ri <'"i
0 <0 N 0 ~ 0 0 ~ <0 0 '" I'-
::;; 1'-, '" 0> "', <Xl ..,., 0 to .. "', N 0
:::> - ~ <Ii ri N ~ <Ii N <O- N ai <D
0 c ~ N <Xl <Xl ., 0 <Xl
Z ::l N N to, 0> N N
W 0 <D
0
0 E ~
<< <(
0 0 <D 0 0 '" 0 0 0 0 <0
'" 0 I'- "' <'! 0 <0 ..,. '" <D
cO M '" M .,,: 0 <ri ai oj I'-
0 <0 ~ '" 0 0 0 I'- I'- ..,.
" 1'-, <0 ..,. to 0, "'- ..,. '" I'-
U r-: "'
'i: <Xl
D.. <0,
-
'c
;;J
C
<( 0 0 0 0 0 0 0 0 0 0
0 C! 0 0 0 0 0 C! C! 0 0
t>: ai ,.-: M <'"i <D N N ,.-: oi
II) ..,. "' N '" <Xl
<{ >- "'- '" ..,. N N
W d '" 00
~ ~ ~
N
tl.
:;;
<(
U
LL -
0 '2 <C <C LL <C i1i >- <( >- >- >-
f- :::l W W ...J W if) W 0 0 0
II)
w
3:
0
I'-f-<(
~c"lt ....
"'<(- 8
a.o; '"
-
ot>:E z 0
M
Ow Z '"
-0" w
lll~if) tl.
0
~ 0
.... oj
.... ~
w C ~ ,
3: w 8 0 '"
t>: w @. z
.... z Q
Q. :5 tl.
~ t. z i'2 '"
0 0 ~ w W f-
'" 0 tl.
<( Co >- >- 0 > z
0 "i: -' -' f- w W
t>: u I1l I1l ~ 0 .... :;;
III :;; :;; i==" cO ;:: w
.... " w w z 0
.... c if) if) I <C z
w e.
3: E if) '" Q 0 8 :::J
<C <C i3 ....
~ w w- z w 0 ~ ~ :c
.... w w :r z 0 z II) Q;-
(5 t9 t9 .... 0 '"
0 t9 0 z z 0 W ::> (jj "
~ ~ 0 ~ <C f- t>: 13
0 ~ :J 0 z ~ :::J " .c 13
0 0 ~ ~ ~ ~ f- " "
I I , 0 0 u 1;) '" 1;)
0 0 ~ ro ro u. .... f= 3: :::J en i; 2 .0
Z Z @. 0:: ...J U c t>: '" 0. 0. Ol
<C <C w w :::l <C :::J <( f- ~ ::> 0. ~
tD tl. a. f- if) a: 0 II) ..,. ~ :";.
0 0 t. t. '"
w :;; ... 0:: 0 " " "
z z w if) "
tl. U W = " "
w w !:: z 0 t3
~ w w z ~ t3 t3
.... -' ~ ~ <( 0 ~ z c
<i: ~ ::;: 0 c c 0
:;; 0 " 0 0 0
a: (!J t9 t9 a: ~ 0 01 0 0
0 0 z $: t9 "tl 2:
w w 0 t9 W 'i: =
0:: a: 0 0 0 LL 0 Z W ~ !!! III III III
<( <( z z Z 0:: <C :::J ~ III III III
:::J :::J W W W W 0 0 0 "tl '" '" '"
t9 t9 u. LL U. tl. 0:: 0 0 ~ C3 C3 0
~ ~
-
'" 0 N "' '" II)
0 N <0 ~ N '" III
N N N N N '"i 0 '" '0;
z , ,}, 0:: m
"' 2> 2> 2> ~
<Xl <Xl ,J, 2> '" " 0
E , , ~ <0 <0 '" ~ ..,. ~ "'
to <0 2> 2> 2> ..... '"
~ '" '" '" 0> 0 Co N N .j.
'" "' '" "' "' E 2> , 2>
'" "' "' 0 0 0
u .. 0 0 0
0 ..,. ..,. ..,.
^_.._.".~m_..____
f"- 0 0> 00 "' <Xl 0 0 0 "' '" 0 0 0 0
'" 0 0 0 00 0 0 0 <0 0 0 to to <Xl
11 r-.: ci r-: ci ... r-.: <Xl ci a:i <Xl ... ci ... oD ci
0> .... 0 I'- N '" 0 00 "' <0 0 CD 00 '" 0
" '" N N '" 1'-, ..,. N N I'- to "' 1'-, <Xl 00, "'-
:::> - ci N ci <Xl N r-: cD .; '" <Ii cD ~ ci <Xl '"
(l ~ 00 N '" ~ '" ~ ..,. ..,. N ~ N
Z " ~ N
W 0
0 E
0
<( <
0 0 0:. 0:. ~ <Xl 0 0 0 I'- "' 0 0 0 0
..,. 0 I'- .... 0 N 0 '" '" 00
r-.: 0 ci ci ci 0 <0 ci N ci M r-.: tC <D ...
N <Xl "' I'- ~ N '" 0 0 '" ..,.
" 0, to, ~ ~ ~ N
u ~ '"
'i:
l1.
-
'2
:>
0-
< 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0
et: <D N oD ... N ci 0 ... ci oD oD c5 oD oD <D
rJl 0 ~ '" '" '" <0 <Xl '" '" '" '" '" '" '"
<( >- ..,., '" I'- <Xl ..,., N '" ~ ~ '" ~
UJ f- N cri "' "'
0 ~ '" ..,.
:<: ~
tl.
:;
<
0
"- -
0 'c >- "- co I1l I1l u. u. < "- u. u. u. "- "- >-
f- ;;J '" 0 -' .... .... .... .... w --' -' .... .... .... --' 0
rJl
UJ
3:
I'- ~<
00 c....
N ....
'" <1: N
, o " -
a> 0
0 a: E "
cw Cl N
-0"
lll;:irJl ~
;;j
t9 ~
....
.... ~ ;;j "
UJ d ~ u
;: '" '"
"-
.... oo Q) Q)
~ a.
~ S '" :0
0 .c ::>
C c: '" 0
< '" Q) t.L 0
l1. >
0 'i: 8 N N ~
a: u '"
.... In '" '" ""
" ~ c
.... C "0 d ~ oj '" ~
w Q) 0> U
3: E .c C/) '0; ~ "0 Q) Cl
" :0- '" '" a: '0; ~ 6 ~
.... '" ~ 'c a:
0 ~ '" 5 ~ Q) '0;
::> iii :0 " ffi ffi a:
13 u. c:
::> Q) ::> a. '0; '0; "
2 13 .c - 0> > 0 ~ a; a;
ro u ~ e. u
"0 10 2 '" Q) ~ co co ,.,
'" :;; 10 e a. 0:: 0> 0> U
tl. ,., Cl 0> iii
0> a. .0 0. t:. Q) '" ~ ~ ~ ~
c: Q) ::> ::> 0. a; U "0 -
'S; c: ~ ~ "'- '" E Q) '0; '0; '0; '0; a;
0 Q) E t .c a: a: a: a:
0 0. a; a; a; '" c: '" '" a.
c'3 0 " Q) Q) Q) 0 c: 'c ]! ]! u u '"
Q) U5 U5 U5 I1l 0 ,., 5 :; :; :;= :;= a;
~ z 0 l" '" tl.
0 0> 0> 01 "0 "0 U. I1l I1l ... .=
0 J!J c: c: ~ Q) Q) "0 '" E E c:
u: 'in "e "e 'e '" '" '" J!J " Q) '"
'" ro ::> ::> a; a; '0; ci
0 ~ ~ 0 0:: c: c: 10
Q) a. S S S .... t t l"
0> E c: c: c: 10 10 10 10 E E Q)
"0 c: c: "0 6.
J5 0 'OJ 'OJ OJ Q) Q) Q) Q) ::> ::> 0 0 "
u a: a: a: 0:: 0:: f- f- <( <( 0 0 a. oc
0
z '"
E I'- '" r- ei, N '"
'1" '? 0> ~ , 0 , ~ '" ~
" ..,. , , ..,. '" ..,. 0 "I "I '*
'" '" ~ ~ ~ ~ ~ '" ~ ~ I'- I'- ~
, , ,;, ,}, , , , , ,;, 0 '" 0
0 0 "' 0 "' to ~ N N
0 0 ~ ~ ~ to "' "' to <0 <0 N '"
..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. ..,. to to "' "'
<Xl 0 CD '" '" '"
<D '" '" ..,. '"
11 M ci N <Xl oi "'
'" "' '" N '"
" '" '" a <0 CD
::> - .; .; M 0 r-: -<i
" c '" ~ ..,. "' N
Z ::l N
W 0
C
0 ~
<(
I'- I'-
<Xl <0
.; ""
I'- <0
"
u
'i:
a.
-
.2 '"
:::J ... ~
'" '"
'" en '" '"
0 ~ :J: ..,. ~
<( .; ci
0 0 0 0
0 0 0
0:: ~ on oi
(/) <Xl '" 0:.,
:;;: >- N '"
W f- ori" co
II:: 0
ll.
:;
<(
0
u. -
0 .c z z u. >- I1l
f- ::> ... ... (f) 0 ....
(/)
w
3:
I'- ~<(
<Xl c'"
N <( - ....
'" C N
en 0 " "6
00:: E on
cw N
-c"
lll~(/)
Cl
....
....
w
3:
....
Q. ~ ~
0
c '" <a
<( a. 1:: '=-
0 'i: OJ
a: u > Co
" :;
.... " 0 ><
.... c >< ""
W
;: E 0 ~
I1l
.... ~ r::- oo 2
(5 I'- V> :J '"
0 :::J
~ OJ OJ
..,. "; '" ~ 1::
'" 1::
0 t5 .!l! OJ
OJ >
0 2 > <ii :;
-'" z ii5 :; 0 0
0 '"
c :11
'" OJ C> 2':.' u
I1l 01 ," OJ
U U
oi ~ 1;; V> <ii 'in
OJ 'x V> OJ "
:0 c w '" ii5
.0 0 0 u OJ
:J - C> .c
ii5 0 0
0:: ci oi c f-
ci: C> ..,. Cii Q) .2 1;;
c + > .E
~ '5 0 t3 '"
'" E ~ 0
6- u I'- c: ';; OJ
C2 OJ ..,. OJ 0 0::
I1l ro a: 0 0::
ii5
ci 1ii ~
1:: '" "?
z OJ 0 1- ~
> ,}, ~
E '" :; ~ a
~ N ..,. ~ 0 ~
I'- 0 ..,. ..,.
, ,
0 a ><
'" '" 0
"' '" I1l
N 0 CO 0 0 0 0 0 "' <Xl 0 <Xl 0 ..,.
0 "!
I'- 0 "' 0 0 '" ~ <0 <Xl '" '--: 0 ..,.
it "" - <Xl .0 "" cO ~ <ri .; <Xl ,.-: <ri
0 r-- r::
'" 0. N "' ~ ~ CO "' N ..,. <0 "' ..,.
:2 N, cO ..,. '" I'- '" I'- ..,. "' '"
::> ~ 0 .; C"i <Xl 00 ci ~
- 0 '"
0 <:: '" '" '"
z " '" N
w 0
0
0 E
<( <(
0 0 0 0 0 0 I'- ~ 0 ;! 0 ..,.
0 "' 0 0 '" '" "' ~ '" "' 0
0 oi M N cO I'- C"i 0 .0 <ri <Xl N
0 N <0 0 <0 ~ '" I'-
" 0 N <0 ~ ~ CO N
U ci N cO
"i: 0
tl. '"
-
'C CO
:::J 0
..;
N
C 1'-.
<( -
0 0 0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0. 0 0 0.
a:: M .0 ,.-: <'"i .0 0 ,.-: N ~
'" <0 ..,. 0 <0
<( >- ..,. ..,. <0
W d N
~
tl.
::;;
<(
0
lL -
0 "" '" en <( <C <C <C LL ::;; :;; LL
f- :::J <C <C w w w w .... z z ....
Ul
w
::
0
I'-f-<(
<XlC'" ....
~<(C '"
cAo G.l -
0
o a: E "'
cw N
-C"
llI;;1ien 0
t9
.... <C
.... en 0
w t9 a:
:: z LL
.... 52 a
Q. ~ a:: c ~
<( z
c 0 oa ::;; w w-
'" 0
<( a. ~ f- r=- ill w :::J -'
0 "i: Z en tl. > .... -'
a: u ro w G::' E- ;:: [J) w
.. a ;;0 G
.... " x .... ::;; '" tl. 0
.... c ;,. <( W N 0 W 0 W ~ ~ N
w ~ w -' :5 @. @.
:: E ~ f- ~ ...J W ~
0 LL '" ~
~ Z <9 f- W I1l 0
.... 2 f- a. <C z z a:: liJ W W W
0 '" en c I G::' :::J Z t: t: t:
:::J W W Z f- en ~ t: a 0 t: 0 I I I
t 0 a:: <( '" "' w ::;; a: I z ~ ~ ~
OJ Z :::J t9 '" N Z f- f- ~ :5
> ~ f- e-:. > :::J W 0 5' 0
:; 0 z w a '" a: en
Z d ~ w 0 tl. = f- f- f-
0 a :> ::;; ...J <e:. f- ;z ~ ~ ~
u .... et: C) f- f- W t9 z '" f-
OJ ...J f- 1jj '" '" ~ z a: w z 0 0 0
u '" a a :;; w <(
';; <( a. a. z Vi W tl. F= ;:: F=
d> '" Y: w 12 a. '" en '"
w = - w w Q ri a:: ;;: w :5 :5 :5
OJ a: ~ >- -' -' en a <( f- >
E a:: t9 t9 ~ ::;; tl. en tl. 0.. tl.
::J <9 F=
f- f- a 0 z z Z f- a: 0 0 0 0 a
~ 0 C) C) Vi Vi w w u: ::;; ::;; :;;
"' F= 0 w
'" :::J W W Z Z z w '" LL -' a: a:: a:
u a:: f- ~ en :J -, a: <( LL W W W
~ f- <( t9 t9 X w '" <( a:: w I I I
a. en 0 0 '" '" w 0 0 ::;; f- a:: f- f- f-
a ;:i 'f- ~ N ~ ..,. ~ ~ N
00 '" 6 ~ I'- 0 <0 <Xl ~
z <h ~ 6 '" '" '" '"' ,
g ~:::J ..,. ..,. .;, <h 6 6 I'- .;,
1" ~ '" '"
E 'a: '" '" 0 ,}, 0 ~ , '?
" of- 0 0 0 I'- I'- 0:. 0:. ~ ~
'" Oen r-- I'- 0 0 0:. 0:.
I'- I'- r::
0 ~ CD CD 0 0 N t- t- O M
N 0 I'- ..,. t- O I'- '" '" 0 M
it ci ci oj .; to N 0 oi to ci N
'" <0 I'- <Xl '" '" '" <0 '" 0 ..,.
:2 0 CO "'- I'- CD ~ ~ 0 0 0
::> - ..,.' N ci N ~ ~ r-: "' 1
0 " ~ N ~
Z " ~
UJ 0
0
0 E
<( <(
..,. '" N ~ 0 0 ..,. N ..,. 0
N '" '" <0 '" '" <Xl '" N 0
M C'"i .; ci r-.: to '" 0 M ci
..,. ..,. CD ..,. 0
" '" ~ <0 0.
u N '"
'i: ~
a.
-
'c
:>
C
<( 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0
a: '" oi M oj C'"i c5 oj r-.: oi
Ul ..,. N '" I'- ..,. '" <0
<( ~ '" 0 ~
w .; N N
~ 0
tl.
:;;
<(
0
u. -
0 'c u. u. :2 u. <( <( :2 u. lJ..
f- ;;J .... .... t9 .... w w z .... ....
Ul
W
;:
0
I'-f-<(
rec"lt I'-
It)<(c: N
mOlD -
0
OCl:E I'-
cw N
-c"
Ill~Ul ....
Cl <(
.... f-
.... 0
W @. f-
3: w '"
.... (jJ U t9
Q. w z z
~ z Co ~ 52
0 ::J (j) @. @. a:
c "" w w (j) ~ 0 <(
<( 0. 0 (9 c 0 0 ...J :;
0 "i: @. <( 5: ...J
Cl: u :::J '" 0 ::J ::J ::J <( f-
In (9 Z
.... " il:" '" Cl: 0 0 0 '"
.... c Co " ot w n:: ~ '" ~ t9 w
w E ~ ~ " t!. 6 "'- ~ ~ z :;;
;: '" ~ ;z w
~ w- w- w- w- w- ill >
.... 0 0 0 a: <(
0 t: t: t: t: t: t: -' -' -' <( tl.
I I I I I I -' -' -' :2
w w w </l
~ ~ ~ ~ ~ ~ c. c. C- f- t9
z
C 0 0 0 0 c 0 0 0 w Z
f- f- f- f- f- f- f- f- f- :2 Z
~ ~ ~ ~ ~ ~ ~ ~ ~ w t9
0 0 0 0 0 0 0 0 0 > (jj
<(
;:: ;:: F= F= F= F= F= ;:: F= tl. I
'" '" '" '" '" '" en '" en 0 -
:5 :5 :5 :5 :5 :5 :s :5 :s z >-
"- tl. tl. a. tl. tl. "- tl. tl. <( a:
0 0 0 0 0 0 0 0 0 t9 0
:;; :;; :2 :2 :2 :2 :2 :2 :2 z t9
n:: a: Cl: n:: n:: Cl: n:: a:: n:: z w
w w w w w w w w w Q ~
I I I I I I I I I
f- f- f- f- f- f- f- f- f- '" 0
c;; ~ ~ :2
ci ~ (0 <Xl <Xl a.
z ~ N '? , '? 'T J:, , ~ en
of, of, '? <0 .;, ,
~ ~ '? '? 0
E '? '? ~ ~ ~ ;::: '? "'
~ ~ ;::: I'- ~ ~ en
~ ~ t- ~
0:. 0:. 0:. ;::: 0:. u
0
MATERIAL MANUFACTURERS
THIS FORM MUST BE COMPLETED OR BID SHALL BE DEEMED NON-
RESPONSIVE
All Bidders shall confirm by signature that they will provide the manufacturers and
materials outlined in this Bid specifications. exceptions (when equals are acceptable)
may be requested by completing the Material Manufacturer Exception List below. If an
exception for a manufacturer and/or material Is proposed and listed below and is not
approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in
the specification. Acceptance of this lann does not constitute acceptance of material
proposed on this list.
Complete and sign section A OR B.
Section A (Acceptance of all manufactures and materials in Bid specifications)
On behalf of my firm, I confinn that we will use all manufacturers and materials
as specifically outlined in the Bid specifications.
n::l:If;/j~l~!f1l1i~RKy
..... .. "i:::~~~ij!i,~:lf~':~~::'::" ii;:.:; ,
."';"':.
Sectton B (exception requested to Bid specifications manufacturers and materials)
EXCEPTION MATERIAL
EXCEPTION MANUFACTURER
1.
2.
3.
4,
5.
Please Insert additional pages as necessary.
G~-3
LIST OF MAJOR SUBCONTRACTORS
THIS LIST MUST BE COMPLETED OR BID MAY BE DEEMED NON.RESPONSIVE
The undersigned states that the following Is a list of the proposed subcontractors for the
major categories outlined in the requirements of the Bid specifications.
The undersigned acknowledges its responsibility for ensuring that the Subcontractors
for the major categories listed herein are "qualified" (as deflned in Ordinance 87-25 and
Section 15 of Instructions to Bidders) and meet alllagal requirements applicable to and
necessitated by the Contract Documents, including, but not limited to proper licenses,
certifications, registrations and Insurance coverage, The Owner reserves the right to
disqualify any Bidder who includes non-compliant or non-qualified Subcontractors in its
bid offer. Further, the Owner may direct the Successful Bidder to remove/replace any
Subcontractor, at no additional cost to Owner. which is found to be non-compliant with
this requirement either before or after the issuance of the Award of Contract by Owner.
(Attach additional sheets as needed). Further, the undersigned acknowledges and
agrees that promptly after the Award of Contract, and in accordance with the
requirements of the Contract Documents, the Successful Bidder shall identify all
Subcontractors it intends to use on the Project. The undersigned further agrees that all
Subcontractors subsequently Identified for any portion of work on this Project must be
qualified as noted above.
1.
2.
3.
4.
5.
6.
7.
Major Category of Work
Carpenters
Elecbicians
Crane Operators
Trucking
Underground Utility
Underground Pipe
Subcontractor and Address
Nt>'" jj..
c,...\tSh,.Xu:; ,..I,,-.\~< t:-\,
\'o\\~<>d- t.r"-"'c.
t"",...c.r-l ~<>-~te.s 'i'"l
!,>~e
J'.\"rl~
C" "lr'::M~]CHlOttWi&.SJ'iIRK"CONS]:RUCTjOl\l'CO"'I'I"IG1:::,:::"
,!,,~~~~!!:i:i.:i':;",.'" 1'.,;'. ...,;'il;~i:::!;::;!ti;ili:!!!::~~~::~,:~:~i~,~,~i~",\,:);:,"::,;',"I'i"i,i',:,'II'"
,,:i;!';'j'~~'O;.';, '
~,Qate.+,A~: _ ::J;!:" ,i;-,
""""",,-,-,-,' '.'.
\';:;" ;:;
'::;::!:::!~I
'-",,,',,.'.,,,, ,',..-,
';'
GC-P4
STATEMENT OF EXPERIENCE OF BIDDER
The Bidder is required to state below what work of similar magnitude completed within
the last five years Is a judge of its experience, skill and business standing and of its
ability to conduct the work as completely and as rapidly as required under the tenns of
the Agreement.
Project and Location
1.
Tl'e.e/,:" 2
f"T #A) w.-f.!: r),
2.
oleA... 'il
goON A-~ sP(",;v.r~
3.
Thf'ee. OA-~~ fc.ri-W6{
f"'d' M'j Br$, Fl.
LorMue..v iLoc-.A.-
For-+- P--'j ~r~, 1" I,
f {r;..."v-l-e.-.-4-f"n:> /lot>....(..
YDr+M.yfd-n PI,
Le.."'""--f '(~k.J-"!' r
f"'--......r LO .J.-S I...~.J F-l.
4.
5.
6.
Dated 11/9/09
BY:
GC-P-5
Reference
M.i'. tZ.........J.'j L.erc.J,~e
Ar.. ~4"""l2..C l-le.J/-o,-J
Mr-. l!...6..rJJ,/ L.e f'd,'e..
Mr. 4<,,/ y Le('J, ~ e
t\..['~ ~'I Ler(..4,'1:.
"",,-[;12&1/,/ -:loel
MITCHELL & STARK CONSTRUCTION CO.. INC,
Bidder
~
~
TRENCH SAFETY ACT
Bidder acknowledges that included in the various items of the bid and in the Total Bid
Price are costs for complying with the Florida Trench Safety Act (90-96. Laws of Florida)
effective October 1, 1990. The Bidder further identifies the cost to be summarized
below:
Trench Safety
Measure
lDescriotlon)
Units of
Measure
ILF.SY)
Unit
IQuantiM
Unit
Cost
Extended
Cost
1. SJop';~
2.
l-F
") DQOD
,..,v
/---
~o. ,,"'n
-
3.
4.
5.
TOTAL
$ 3D Do<=>
,
Failure to complete the above may result in the Bid being declared non-responsive,
Dated 11/9/09
MITCHELL & STARK CONSTRUCTION CO" INC,
Bidder
BY: ~
GC-P-6
e&Cowd;y
~ -~ ~
Ad I. lilAe6e ServioIls I:MliOO"
PuI1:tlail1g
Affidavit fOf" Claiming Status as a Local Business
Bid #: Og.qJ!87 . OU Wen Road Widening. Segments 2 and 4A
(CHECK APPROPRIATE BoXES BELow)
Slate O~lorfda (Select County If Vendor Is described as a Local Business
oilier County
Lee County
Vendor affirms that It Is a local business as defined by the Purchasing Polley of the Collier County Board of County
Comm Issioners and the Regulations Thereto,
As defined In Section XI of the Collier County Purchasing Polley;
A "local business" is defined as a business that has a valid occupational license issued by either Collier or Lee
Counly for a minimum of one (1) year prior to a Collier County bid or proposal subm Isslon that authoriZes the
business to provide the commodities or services to be purchased, and a physical business address located within
the limits of Collier or Lee Counties from which the vendor operates or performs business, Post Office Boxes are
not verifiable and shall not be used for the purpose of establishing said physical address, In addkion to the
foregolng, a vendor shall not be consJdered a "local business" unless it contributes \0 the economic development
and well-being of either Collier or Lee County in a verifiable and measurable way, This may include. but not be
limited to, the retention and expansion of employment opportunities, the support and Increase to either Collier or
Lee County's tax base, and resldencyof employees and principals of the business within Collier or Lee County,
Vendors shall affum In writing their compliance with the foregoing atlhe time of submitting their bid or proposal to
be eligible for consideration as a "local business" under this section,
Vendor must complele the following information:
Year Business Established in SCoIlier County or 0 Lee County: 5-2-1980
Number of Employees (Including OWner(s) or Corporate Officers): 192
Number of Employees Living in t)ltCollier County or 0 Lee (Including Owner(s) or Corporate OffICers): 62
If requested by the County. vendor will be required to provide documentation substantiating the information 9iven in this
affidavit. FaHure to do so will result in vendor's submission being deemed not applicable,
Vendor Name: MITCHELL & STARK CONSTRUCTiON CO.. INC,
Signature: ~IAN PENNER
STATE OF FLORIDA
1il COLLIER COUNlY 0 LEE COUNlY
Sworn to and Subscribed Before Me, a Notary Public, for the above State and County, on this
NOVEMBER, 2009 '/2
BELINDA BURGBACH\t..R ~ft----
_ _ ~ NOTARYPUBLlC-STATEOFFLORlDA
Notary Public I <i;;;t.., Belinda Burgbacher
~..} ~o~rr,jssioo HVD6204SS
My Commission Expires: 1/2211 t .........,.' Expires, JAN, 22. 2011
llONDZO 'lWH1 ^TLAN11c MINDING CO., me.
Date, 11/9/09
Hie: CEO
9
Day of
(AFFIX OFFICIAL SEAL)
GC-P-7
~~
- - - -
Ado,' I5tldlioe SeMces 0Msi0n
Pun:l1amg
Immigration Affidavit Certification
Bid': 09-5287
TItle: Oil Well Road Widening - Segments 2 and 4A
This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with
forma/Invitations to Bid (lTB's) and Request for Proposals (RFP) submittals. Failure to include this Affidavit with
proposal will delay In the consideration and reviewing of vendor's proposals and could result in the vendor's
proposal being deemed non-responsive.
Collier County will not intentionally award County contracts to any vendor who knowingly employs unauthorized
alien workers, constituting a violation of the employment provision contained in 8 U,S.C. Section 1324 ale) SecUon
274A(e) of the Immigration and Nationality Act ('INA').
Collier County may consider the employment by any vendor of unauthorized aliens a violation of Section 274A (e)
of the INA. Such Vi6latlon by the recipient of the Employment Provisions contained in Section 274A (e) of the INA
shall be grounds for unilateral termination of the contract by Collier County.
Vendor attests that they are tufty compliant with all applicable immigration laws (specifically to the 1986 Immigration
Act and subsequent Amendment(s)) and agrees to abide by Collier County Employment Eligibility VerifICation
System requirements regarding this solicitation.
Company Name
MITCHElL & STARK CONSTRUCTION CO., INC.
Print Name
Signature
BRIAN PENNER
~~
'----
Tme CEO
Date 11/9/09
STATE OF COLLIER
COUNTY OF FLORIDA
The foregoing Instrument was signed and acknowledged befora ma this 9
2009 , by
day of NOVEMBER
BRIAN PENNER
(Print or Type Name)
KNOW PERSONALLY
Type of Identification and Number)
who has produced
as identifICation,
NOTARY PUBLIC-STATE OF FLORIDA
."''''''''', Belinda Burgbacbi'
~~ J ~o,!missio(1 # I>D62045.5
......""..'. Exp,res: JAN. 22,2011
1>O:NllED TRRU ATIANfIC BONDING CO., me.
BELINDA BURGBACHER
Printed Name of Notary Public
00620455/1/22/11
Notary Commission Number/Expiration
The si9nee of this Affidavit gU8l8neees, as evidenced by the sworn affidavit reqUired herein, the truth and accuracy
of this affidavtt to Interrogatories hereinafter made. Collier County reserves the right, at any time, to request
supporting documentation as evidence of the vendor's compliance with this sworn affidavit,
GC-P-8
Upon notification that Its Bid has been awarded, the Successful Bidder will execute the
. Agreement fonn attached to the Bidding Documents within ten (10) calendar days and deliver
the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents.
The bid security attached is to become the property of the Owner in the event the Agreement,
Insurance Certificates and Bonds are not executed and delivered to Owner within the time
above set forth, as liquidated damages, for the delay and additional expense to the OWner, it
being recognized that, since time is of the essence, OWner will suffer financial loss if the
Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance
Certificates and Bonds within the required time period. In the event of such failure, the total
amount of Owner's damages, will be difficult, if not impossible. to definitely ascertain and
quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated
damages from the Successful Bidder in the event it fails to execute and deliver the Agreement,
Insurance Certificates, and Bonds as required hereunder. The Successful Bidder hereby
expressly waives and relinquishes any right which it may have to seek to characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder
fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely
manner.
Upon receipt of the Notice of Award, the undersigned proposes to commence work at the site
within 5 calendar days from the commencement date stipulated in the written Notice to Proceed
unless the Project Manager. in writing, subsequently notifies the Contractor of a modified (later)
commencement date. The undersigned further agrees to substantially complete all work
covered by this Bid wIthin the consecutive calendar days specified below, computed by
excluding the commencement date and including the last day of such period, and to be fully
completed to the point of final acceptance by the Owner within the consecutive calendar days
after Substantial Completion, computed by excluding commencement date and including the
last day of such period.
Project Name Days Days
Substantial ComDlfltion Final
Segment 2 720 30 - Total 750
Segment 4A 735 30 Total 765
RespectfullY Submitted:
State of FLORIDA
County of COLLIER
BRIAN PENNER , being first duly sworn on oath
deposes and says that the Bidder on the above Bid is organized as indicated and that all
statements herein made are made on behalf of such Bidder and that this deponent is authorized
to make them.
BRIAN PENNER , also deposes and says that it
has examined and carefully prepared its Bid from the Bidding Documents, including the Contract
Drawings and Specifications and has checked the same in detail before submitting this Bid; that
the statements contained herein are true and correct.
GC-p,g
(a) Corooration
The Bidder is a corporation organized and
INDIANA ,which operates
MITCHELL & STARK CONSRUGTION GO" lNG,
as follows:
existing under the laws of the State of
under the legal name of
, and the full names of its officers are
President FRED HARRISON
Secretary BRIAN PENNER
Treasurer FRED HARRISION
Manager BRIAN PENNER
The BRIAN PENNER
contracts for the company
12/28/06
last sentence if not applicable).
is authorized to sign construction bids and
by action of its Board of Directors taken
, a certified copy of which is hereto attached (strike out this
(b) Co-Partnershio
The Bidder is a co-partnership consisting of individual partners whose full names are as follows:
The co-partnership does business under the legal name of:
(cl Individual
The Bidder is an individual whose full name is
operating under a trade name, said trade name is
DATED 11/9/09
, and if
~l..lA.JI.A~
Witness
l--<>r" P I
legal entity
BY: MITCHELL & STARK GONST, GO" lNG,
N~er(T~l
Signature
Witness
GEO I" /p
Title
GC,P-10
STATE OF R
COUNTYOF ('i"Il/,'P/"""
The fOregOin~in~trument was acknowledged before me this l day of II . 2009,
by '~~ ~= ,as GCi::6 of
/;-;;1,--1"-1/ -I-:2<i (' '" ro>,:r;:P:a .:C---""d'dA-LL corporation, on behalfofthe
corporation. J:le/She is personally known to me or has produced
- - - - - as identification and did
(did not) take an oath.
'~'o\kY l'l!IlLlC-STA!E or FLORIDA
":;'" Belinda Burgbacher
. 1 Commission #DD620455
. "'pires: JAN. 22, 2011
,; ",. ,\TlANI1C BONnINGCO., me.
NAME:
~~~.
(Signa re of Notary)
,l?"'~A~ ,IfrLrc.6At-..h/"""
(Legibly Printed) u
My Commission Expires:
(AFFIX OFFICIAL SEAL)
Notary Public, State of ;::/
Commission No.: .z;ZiC...2Df-'~--
NOTARY pUllUC-STATll or l'LORlnA
,""""',- Belinda flurgbacher
f W i Commission # D0620455
\"f Bxpires: JAN, 22, 2011
liON-UEb TH.RO ATLANTIC BONDING co.,me.
GC-P-11
--)~
BID BOND
KNOW ALL MEN BY THESE PRESENTS, that we Mitchell and Stark Construction
Co.. Inc. (herein after called the Principal) and Fidelity and Deoosit Comoanv of Marvland
(herein called the Surety), a corporation chartered and existing under the laws of the state of
Marvland with its principal offices in the city of Baltimore and authorized to do business in the
State of Florida are held and firmly bound unto the Collier County Board of Commissioners
(hereinafter called the Owner, in the full and just sum of Five Percent of Maximum Bid
Amount dollars ($ 5% ) good and lawful money of the United States of America, to be paid
upon demand of the Owner, to which payment well and truly to be made, the Principal and the
Surety bind themselves, their heirs, and executors, administrators, and assigns, jointly and
severally and firmly by these presents.
Whereas, the Principal is about to submit, or has submitted to the Owner, a proposal for
furnishing all labor, materials, equipment and incidentals necessary to furnish and install:
Bid No. 09-5287 Oil Well Road Wideninll Se2ements 2 and 4A
NOW, THEREFORE: The conditions of this obligation are such that if the Proposal be
accepted, the Principal shall, within fifteen days after the date of a written Notice of Award,
execute a Contract in accordance with the Proposal and upon the terms, conditions and price(s)
set forth therein, of the form and manner required by the Owner, and execute a sufficient and
satisfactory Contract Perfonnance Bond and Payment Bond payable to the Owner, in an amount
of 100 Percent of the total Contract price each in a form and with security satisfactory to the said
Owner, then this obligation to be void; otherwise to be and remain in full force and virtue in the
law; and the Surety shall, upon failure of the Principal to comply with any or aU of the foregoing
requirements within the time specified above, immediately pay to the aforesaid Owner, upon
demand, the amount hereof in good and lawful money of the United States of America, not as a
penalty but as liquidated damages.
IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly
signed and sealed this 9th day of November . 2009
MITCHELL AND STARK CONSTRUCTION CO.. INC.
:~ciPal ~ ~
, (Seal)
FIDELITY
Surety
By
(Seal)
Robert E. W' Iiams, Jr. - Attorney-in-fact
Countersigned
Local Resident Producing Agent for Florida
BID BOND
KNOW ALL MEN BY THESE PRESENTS, that we Mitchell and Stal'){ Construction
Co,. fnc, (herein after called the Principal) and Fidelity and DeDosit Comnanv of Mar vIand
(herein called the Surely), a corporation chaJiered and existing under the laws oflhe state of
MaQ'land with its principal offices in the city of Baltimore and authorized to do business in the
State of Florida are held and Iilmly bound unto the Collier County Board of Commlsslonel's
(hercinafter called the Owner, in the full and jnst sum of Five Percent of Maximum Bid
Amonnt dollars ($ 5% ) good and lawful money of the United States of America, to be paid
upon demand of the Owner, to which payment well and tnlly to be made, the Principal and the
Surety bind themselves, their heirs, and executors, administrators, and assigns, jointly and
severally and finnly by these presents.
Whereas, the Principal is about to submit, or has submitted to the Owner, a proposal for
furnishing all labor, materials, equipment and incidentals necessary to furnish and install:
Bid No. 09-5287 Oil Well Road Widenin!! Se!!mellt 2
NOW, THEREFORE: The conditions of this obligation are such that if the Proposal be
accepted, the Principal shall, within fifteen days after the date of a written Notice of Award,
execute a Contract in accordance with the Pl'Oposal and upon the terms, conditions and price(s)
set forth therein, of the fonn and maMcr required by the Owner, and execute a sufficient and
satisfactory Contract PerfOlmance Bond and Payment Bond payable to the Owner, in an amOl.mt
of I 00 Percent ofthe total Contract price each in a fonn and with security satisfactory to the said
Owner, then this obligation to be void; otherwise to be and remain in full force and virtue in the
law; and the Snretyshall, upon faihlre of the Principal to comply with any or all oflhe foregoing
requirements within the time specified above, immediately pay to the aforesaid Owner, npon
demand, the amount hereofin good and lawful money of the United States of America, not as a
penalty but as liquidated damages.
IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly
signed and sealed this 18th day of November ,2009
MITCHELL AND STARK CONSTRUCTION CO.. INC.
Principal ~ _ _______
By ~
(Seal) y
FIDELITY
Surety
By
(Seal)
OF MARYLAND
Countersigned
Local Resident Producing Agent for Florida
Power of Attorney
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
KNOW ALL MEN BY TIIESEPRESENTS: That the FIDELITY AND DEPOSIT COMPANY OFMARYLAND,'
corporaUon ofthe Slate of Mlll)Iland, by WILLIAM J. MILLS, Vice President, and ERIC D. BARNES, Assistant Secretary,
in pursuance of authorily granted by Article VI, Section 2, of the By-Lnws ohaid Company, are seHorth on the
revene side hereofand fire hereby certified to be in full foree and effecl on thedat h by nominate, consUtute
and appoint Anthony E. ORTMAN, Jo'HOLLINGSWORTH and of Indianapolis,
Indiana,EACH its true and lawful agenl and Allomey-in-F ,and on its behal! as
surely, and as its act and deed: any and all bon ,.Il'l~ uc bonds or undertakings In
pursuance of these presents, sba~1 be as ' . 0 ~~ ply, to all inlents and purposes, as If they
had been duly executed and ack e re i dif.I:l!rs of Ihe Company at its office in Baltimore, Md., In
their own proper pe~~ f~o ssued on behalf of Anthony E. ORTMAN, Andrew M.
HATHEWAY,Jo~'tM'dJ:~'8!!fi rM.JOACRIM,datedAugust29,2005.' .
The said AssiSlllnt ~ ~ certify that the exlracl set forth on !he reverse side hereof is a lrUe copy of Article VI,
Section 2, oflbe By-~dc;,mpany, and is now in force. , '
IN WITNESS WHEREOF, the said Vice.President and Assistant Secretary have hereunlo subscribed their names and
affIXed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY Of lYfAIl,YLAND, this 23rd day ofJanuary,
A.D. 2007. ..
A Tl'EST:
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
~}),~
By:
Assistant Secretar)' William J. MUls
/-'1'1/
Eric D. Barnes
Vice President
Stale of Maryland }ss.
City of Baltimore . .
On tWs 23rd day of lanuDr)', A,D. 2007, before the subscriber, 0 NOllll)l Publlc of the Slate of Maryland, duly
commissioned nnd qualified, came WILLIAM J. MILLS, Vice President, and ERIC D. BARNES, Assislant Secretary of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me pcrsonally known to be Ibe IndivIduals and officers'
described in and who executed lhe preceding instrument, and they each acknowledged the execution of the same, and being
by me duly sworn, severally and each for himself deposelh aad saith, lhnllhcy ore the .ald officer. of Ihe Company aforesaid,
and that the seal affixed 10 the preceding instrument is the Corporale Seal of said Company, and that tbe said Corporale Seal
and their signatures as such officers were duly nfflxed and subscribed 10 Ihesaid instrument by lhe uuthorlty and direction of
lhe said Corporation,
IN TESTIMONY WHEREOF, I have hereunto set my hand and amxed my Official Seal the day and year first above
written.
",\~tIlIIUI/"
'..'~~~~;.b6ti.~"";~
, $. unl ~.'"
:t ,( . o\ttJ. ~i
~ ("'. w
\~~,,,,..(;p,)
<-;"..tti\lr~\~"\;
'r'"n\'
~Da0J2
Maria D. Adamski Notary Public
My Commission Expires: luly 8,2011
POA,F 044,A
EXTRACT FROM BY.LAWS OF FIOELITY ANO OEPOSIT COMPANY OF MARYLAND
"Arlicle VI, Seclion 2, The Chllirm.n of Ihe Board, or lhe Presidenl, or any Execulive Vice, President, or any of Ihc Senior
Vice-Presidents or Vice-Pre!l!den~< specially authorized so 10 do by lhe Board of Directors or by the Execntive Commiltee.
shall have power, by and with lhe concurrence of the Secretary or anyone of the Assistant Secretaries, to appoint Resident
Vlce,Presldenls. Assisl.nl Vice-Presidents and AUOIneys-in,FacI as Ihe business of lbe Company may require, or 10
authorize all)' person or persons to execute on behalf of the Company any bond.~l undertaking, recognizances, stipulations.
policies, contl'8cts, agreements, deeds, and relellScs and ~s5jgnments of judgements, decrees, mortgages ftIld instruments in
the nalure of mortg.ges.....nd 10 affix lhe seal of lbe Comp.ny therelo."
CERTIFICATE
I, tbe undersigned, Assistanl Seeret.ry of lhe FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify
Ih., the foregoing Power of AUoroey is slill ia "ill force and effect on the d.le of thi.. cortilie'le; nad I do furlher cerlify lh.1
the Viee,Presidenlwho executed the said Power of Attorney was o"e of the additional Vice,Presi<1cnts specially aUlhor;zed
by ihe Board of Directors 10 .ppoinl .ay Altorney,jn,Fael .s providcd in Article VI. Seclioll 2. of Ihe By-Laws of thc
FIDELITY AND DEPOSIT COMPANY OF MARYLAND.
This Power of Altomey and Cerlificale mny be signed by facsimile uadel' and by anlhorily of Ihe following rosolulion of Ihe
Board of Direclors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND nl . meeting duty called II,nl held ou
Ihe 10111 day of May. 1990.
RESOLVED: "TIlal the facsimile or mcchanicany reproduced senJ of lhe comp.ny and facsimile or mechanically
reproduced signnlure of any Vice-President, Secrelary. or AssJstant Secretory of the Company, whether made heretofore or
hereafter, wherever appearing upon n certified copy of any power of attorney isslIed by the Company. shull he vlIlid nnd
binding upon the Company with lhe .ame force and effecl as though manually affixed,"
IN TESTIMONY WHEREOF, J h.ve hereunto subscribed my name and .ffixcd tbe corporale seal of Ihe said Company,
lhis
/;>1"
day of ..vI!> V e,bf.1 ~ ,u'
. J.tJ{)9,
J~I/ :; /./.-tJ
Anfs(QIll Sl!crclat}'
THIS SHEET MUST BE SIGNED BY VENDOR
BOARD OF COUNTY COMMISSIONERS
COWER COUNTY, FLORIDA
Purchaaing Dapartmant
BIDDERS CHECK LIST
IMPORTANT: Please read carefully, sign In the spac.. Indicated and I!1Ym with
your Bid.
Bidder should check off eac;h of the following Items as the necessary action is completed:
J 1, The Bid has "-" signed.
\.- 2. The Bid prices offered have been reviewed.
v 3. The prlce IllCleI1sions and lolals heve been checked.
~ 4, Any required drawings, descrlptiWJ IiteratLA, ete. have been included.
, 5. Any delivery InfonnaUon required Is included.
"6. Local Vendor Preference Amdallit completed.
J 7, Immigration Affidavit Completed
"8. If required, the amount of Bid bond has been checked, and the Bid bond or cashiar's
check has been included.
IJ 9. Any addenda ha... been signed and included.
10. The mail~ envelope has been addressed to:
Purchasing Director
Collier County Govemman t Center
PurchasIng Building
3301 Tamlami Trail, East
Naples, Florida 34112
11. Tha mailing anvelope Illl.Ii1 ba ~ and markad wilh:
e>B1d Number
..,Project Name
eoOpanlng Dete
12. The Bid will be mailed or dalivered in time to be recelvad no later than the specified
ooenlna date and time, olhalwise Bid cannot be considered.
ALL COURlER..oELIVERED BIDS MUST HAVE THE BID NUMBER
AND PROJECT NAME ON THE OUTSIDE OF THE COURIER PACKET
MITCHELL & STARK CONSTRUCTION CO.. INC,
~I rName
BRIAN PENNER CEO
Signature & Title
Date: 11/9/09
GC-P-13
CONSTRUCTION AGREEMENT
THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA,
("Owner") hereby contracts with Mitchell & Stark Construction Co" Inc, ("Contractor") of
6001 Shirley Street, Naples, Florida, 34109, an Indiana company, authorized to do
business in the State of Florida, to perform all work ("Work") in connection with Oil Well
Road Widening - Segments 2 and 4A, Bid No, 09-5287 ("Project"), as said Work is set
forth in the Plans and Specifications prepared by CH2M Hill, the Engineer and/or
Architect of Record ("Design Professional") and other Contract Documents hereafter
specified. Owner and Contractor, for the consideration herein set forth, agree as
follows:
Section 1.
Contract Documents.
A. The Contract Documents consist of this Agreement, the Exhibits described in
Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly
executed and issued addenda, Change Orders, Work Directive Changes, Field Orders
and amendments relating thereto, All of the foregoing Contract Documents are
incorporated by reference and made a part of this Agreement (all of said documents
including the Agreement sometimes being referred to herein as the "Contract
Documents" and sometimes as the "Agreement" and sometimes as the "Contract"), A
copy of the Contract Documents shall be maintained by Contractor at the Project site at
all times during the performance of the Work,
B, Owner shall furnish to the Contractor one reproducible set of the Contract
Documents and the appropriate number of sets of the Construction Documents, signed
and sealed by the Design Professional, as are reasonably necessary for permitting.
Section 2.
Scope of Work.
Contractor agrees to furnish and pay for all management, supervision, financing, labor,
materials, tools, fuel, supplies, utilities, equipment and services of every kind and type
necessary to diligently, timely, and fully perform and complete in a good and
workmanlike manner the Work required by the Contract Documents,
Section 3.
Contract Amount.
In consideration of the faithful performance by Contractor of the covenants in this
Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or
cause to be paid, to Contractor the following amount (herein "Contract Amount"), in
accordance with the terms of this Agreement: Thirty-Nine Million One Hundred Eighty-
Four Thousand Nine Hundred Ninety-Nine Dollars and Eighteen Cents
($39,184,999,18), (This includes the base bid of $34,977,999,18 and allowances of
$4,207,000.00,)
GC-CA-14
Section 4. Bonds.
A. Contractor shall provide Performance and Payment Bonds, in the form
prescribed in Exhibit A, in the amount of 100% of the Contract Amount, the costs of
which are to be paid by Contractor. The Performance and Payment Bonds shall be
underwritten by a surety authorized to do business in the State of Florida and otherwise
acceptable to Owner; provided, however, the surety shall meet the requirements of the
Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority
as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies"
circular, This circular may be accessed via the web at
www,fms,treas,gov/c570/c570,html#certified, Should the Contract Amount be less than
$500,000, the requirements of Section 287,0935, F,S, shall govern the rating and
classification of the surety,
B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business is terminated in the State of Florida, or it ceases to
meet the requirements imposed by the Contract Documents, the Contractor shall, within
five (5) calendar days thereafter, substitute at its cost and expense another bond and
surety, both of which shall be subject to the Owner's approval.
Section 5.
Contract Time and Liauidated Damaaes.
A. Time of Performance.
Time is of the essence in the performance of the Work under this Agreement. The
"Commencement Date" shall be established in the written Notice to Proceed to be
issued by the Project Manager, as hereinafter defined. Contractor shall commence the
Work within five (5) calendar days from the Commencement Date, No Work shall be
performed at the Project site prior to the Commencement Date. Any Work performed by
Contractor prior to the Commencement Date shall be at the sole risk of Contractor.
Contractor shall achieve Substantial Completion within seven hundred and twenty
(720) calendar days for Segment 2 and seven hundred and thirty five (735) calendar
days for Segment 4A from the Commencement Date (herein "Contract Time"), The
date of Substantial Completion of the Work (or designated portions thereof) is the date
certified by the Design Professional when construction is sufficiently complete, in
accordance with the Contract Documents, so Owner can occupy or utilize the Work (or
designated portions thereof) for the use for which it is intended, For both segments,
Contractor shall achieve Final Completion within thirty (30) calendar days after the date
of Substantial Completion, Final Completion shall occur when the Agreement is
completed in its entirety, is accepted by the Owner as complete and is so stated by the
Owner as completed, As used herein and throughout the Contract Documents, the
phrase "Project Manager" refers to the Owner's duly authorized representative and shall
mean the Division Administrator or Department Director, as applicable, acting directly or
through duly authorized representatives,
B. Liquidated Damages in General.
Owner and Contractor recognize that, since time is of the essence for this Agreement,
Owner will suffer financial loss if Contractor fails to achieve Substantial Completion
within the time specified above, as said time may be adjusted as provided for herein. In
GC-CA-15
such event, the total amount of Owner's damages, will be difficult, if not impossible, to
definitely ascertain and quantify, Should Contractor fail to achieve Substantial
Completion within the number of calendar days established herein, Owner shall be
entitled to assess, as liquidated damages, but not as a penalty, based on contract
price per Section 8 of 2007 FOOT for each calendar day thereafter until Substantial
Completion is achieved. Further, in the event Substantial Completion is reached, but
the Contractor fails to reach Final Completion within the required time period, Owner
shall also be entitled to assess and Contractor shall be liable for all actual damages
incurred by Owner as a result of Contractor failing to timely achieve Final Completion,
The Project shall be deemed to be substantially completed on the date the Project
Manager (or at his/her direction, the Design Professional) issues a Certificate of
Substantial Completion pursuant to the terms hereof. Contractor hereby expressly
waives and relinquishes any right which it may have to seek to characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if
Contractor fails to Substantially or Finally Complete the Work within the required time
periods,
C, Computation of Time Periods,
When any period of time is referenced by days herein, it shall be computed to exclude
the first day and include the last day of such period. If the last day of any such period
falls on a Saturday or Sunday or on a day made a legal holiday by the law of the
applicable jurisdiction, such day shall be omitted from the computation, and the last day
shall become the next succeeding day which is not a Saturday, Sunday or legal holiday.
D. Determination of Number of Days of Default.
For all contracts, regardless of whether the Contract Time is stipulated in calendar days
or working days, the Owner will count default days in calendar days,
E, Right of Collection.
The Owner has the right to apply any amounts due Contractor under this Agreement or
any other agreement between Owner and Contractor, as payment on such liquidated
damages due under this Agreement in Owner's sole discretion, Notwithstanding
anything herein to the contrary, Owner retains its right to liquidated damages due under
this Agreement even if Contractor, at Owner's election and in its sole discretion, is
allowed to continue and to finish the Work, or any part of it, after the expiration of the
Contract Time including granted time extensions,
F, Completion of Work by Owner,
In the event Contractor defaults on any of its obligations under the Agreement and
Owner elects to complete the Work, in whole or in part, through another contractor or its
own forces, the Contractor and its surety shall continue to be liable for the liquidated
damages under the Agreement until Owner achieves Substantial and Final Completion
of the Work, Owner will not charge liquidated damages for any delay in achieving
Substantial or Final Completion as a result of any unreasonable action or delay on the
part of the Owner.
GC-CA-16
G. Final Acceptance by Owner,
The Owner shall consider the Agreement complete when the Contractor has completed
in its entirety all of the Work and the Owner has accepted all of the Work and notified
the Contractor in writing that the Work is complete, Once the Owner has approved and
accepted the Work, Contractor shall be entitled to final payment in accordance with the
terms of the Contract Documents,
H, Recovery of Damages Suffered by Third Parties,
Contractor shall be liable to Owner to the extent Owner incurs damages from a third
party as a result of Contractor's failure to fulfill all of its obligations under the Contract
Documents. Owner's recovery of any delay related damages under this Agreement
through the liquidated damages does not preclude Owner from recovering from
Contractor any other non-delay related damages that may be owed to it arising out of or
relating to this Agreement.
Section 6.
Exhibits Incorporated.
The following documents are expressly agreed to be incorporated by reference and
made a part of this Agreement.
Exhibit A:
Exhibit B:
Exhibit C:
Exhibit D:
Exhibit E:
Exhibit F:
Exhibit G:
Exhibit H:
Exhibit I:
Exhibit J:
Exhibit K:
Exhibit L:
Exhibit M:
Exhibit N:
Performance and Payment Bond Forms
Insurance Requirements
Release and Affidavit Form
Contractor Application for Payment Form
Change Order Form
Certificate of Substantial Completion Form
Final Payment Checklist
General Terms and Conditions
Supplemental Terms and Conditions
Technical Specifications
Permits
Standard Details (if applicable)
Plans and Specifications prepared by CH2M Hill
and identified as follows: Oil Well Road Widening - Segments 2
and 4A as shown on Plan Sheets 1 through 570,
Contractor's List of Key Personnel
Section 7. Notices
A. All notices required or made pursuant to this Agreement by the Contractor to the
Owner shall be shall be deemed duly served if delivered by U,S, Mail, E-mail or
Facsimile, addressed to the following:
Gary Putaansuu, Project Manager
Transportation Engineering & Construction Management (TECM)
2885 S. Horseshoe Drive
Naples, Florida 34102
(239) 252-5876
GC-CA-17
B, All notices required or made pursuant to this Agreement by Owner to Contractor
shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-
mail or Facsimile, addressed to the following:
Brian Penner, CEO
Mitchell & Stark Construction Co" Inc.
6001 Shirley Street
Naples, FL 34109
Telephone No. : (239) 597-2165
Fax No,: (239) 566-7865
C, Either party may change its above noted address by giving written notice to the
other party in accordance with the requirements of this Section,
Section 8.
PUBLIC ENTITY CRIMES.
8,1 By its execution of this Contract, Construction Contractor acknowledges that it
has been informed by Owner of the terms of Section 287,133(2)(a) of the Florida
Statutes which read as follows:
"A person or affiliate who has been placed on the convicted
vendor list following a conviction for a public entity crime may not
submit a bid on a contract to provide any goods or services to a
public entity for the construction or repair of a public building or
public work, may not submit bids on leases of real property to a
public entity, may not be awarded or perform work as a contractor,
supplier, subcontractor, or consultant under a contract with any
public entity in excess of the threshold amount provided in s.
287.017 for CATEGORY TWO for a period of 36 months from the
date of being placed on the convicted vendor list."
Section 9.
Modification.
No modification or change to the Agreement shall be valid or binding upon the parties
unless in writing and executed by the party or parties intended to be bound by it.
Section 10.
Successors and Assiqns.
Subject to other provisions hereof, the Agreement shall be binding upon and shall inure
to the benefit of the successors and assigns of the parties to the Agreement.
Section 11.
Governinq Law.
The Agreement shall be interpreted under and its performance governed by the laws of
the State of Florida.
GC-CA-18
Section 12.
No Waiver.
The failure of the Owner to enforce at any time or for any period of time anyone or
more of the provisions of the Agreement shall not be construed to be and shall not be a
waiver of any such provision or provisions or of its right thereafter to enforce each and
every such provision,
Section 13.
Entire Aareement.
Each of the parties hereto agrees and represents that the Agreement comprises the full
and entire agreement between the parties affecting the Work contemplated, and no
other agreement or understanding of any nature concerning the same has been entered
into or will be recognized, and that all negotiations, acts, work performed, or payments
made prior to the execution hereof shall be deemed merged in, integrated and
superseded by the Agreement.
Section 14.
Severability.
Should any provision of the Agreement be determined by a court to be unenforceable,
such a determination shall not affect the validity or enforceability of any other section or
part thereof,
Section 15.
Chanae Order Authorization.
The Project Manager shall have the authority on behalf of the Owner to execute all
Change Orders and Work Directive Changes to the Agreement to the extent provided
for under the Owner's Purchasing Policy and accompanying administrative procedures,
Section 16.
Construction.
Any doubtful or ambiguous language contained in this Agreement shall not be
construed against the party who physically prepared this Agreement. The rule
sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in
a contractual term which appears on its face to have been inserted for the benefit of one
of the parties shall be construed against the benefited party) shall not be applied to the
construction of this Agreement.
Section 17.
Order of Precedence
In the event of any conflict between or among the terms of any of the Contract
Documents, the terms of the Construction Agreement and the General Terms and
Conditions shall take precedence over the terms of all other Contract Documents,
except the terms of any Supplemental Conditions shall take precedence over the
Construction Agreement and the General Terms and Conditions, To the extent any
conflict in the terms of the Contract Documents cannot be resolved by application of the
Supplemental Conditions, if any, or the Construction Agreement and the General Terms
and Conditions, the conflict shall be resolved by imposing the more strict or costly
obligation under the Contract Documents upon the Contractor at Owner's discretion,
GC-CA-19
IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s)
indicated below,
CONTRACTOR:
AOW'~~
. ~~WITNESS
~el,~ i!(NJ!~d~
Type/Print e
r=-rz- {~
SECOND WITNESS ____:J
elL (} AJ/;, ~I\J i; etL(,.-
Type/Print Name
Mitchell & Stark Construction Co" Inc,
'-~~
By:
Sf' )~.v feA,Uve.r LEo/VI/,
Type/Print Name and Title
Date: Ho~(}'CtO
OWNER:
ATTEST:
C",'-"
." '
BOARD OF COUNTY COMMISSIONERS OF
COLLIER COUNTY FL.QRIDA
J;
,... '
"
.I; I "..j-:, /J
BY: h, t+,...,.?,~ . ,."., ,,<t ,e,;,c
Donna fiala, Chairman
. ~ . .. ., '. ..ii.
DwightE, 8f~8k;GJe~!, ... "
By~K~(.
Appld1l4t Jr_8tm
and Legal Sufficiency:
Print Name: ~ f1? j~ L
Ac:c:i..t;;u;:It County Attorney
~
GC-CA-20
- .---,....-- ......
EXHIBIT A
PUBLIC PAYMENT BOND
011 Well Road Widening. Segments 2 and 4A
Bond No. 0$'17 '1fJ07
Contract No. 09-5287
KNOW ALL MEN BY THESE PRESENTS: That Mitchell & Stark Construction Co.. Inc,
, as Principal,
and Fidelity & DeDosit ComDanv of Marvland , as
Surety, located at 9229 Deleaates Row Suite 300. IndianaDolls, IN 46240
(Business Address) are held and finnly bound to The Board of Coun\y Commissioners
Collier County Florida'. as Obligee In the sum of Thirty-nine Million. One Hundred
Eiahty-four. Nine Hundred Ninety-nine dollars and elahteen Cents ($39,184,999,18 ) for
the payment whereof we bind ourselves, our heirs, executors, personal representatives,
successors and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the ...!.!e..- day of
December 2009, with Obligee for Oil Well Road Seaments 2 and 4
in accordance with drawings and specifications, which
contract is incorporated by reference and made a part hereof, and is referred to herein
as the Contract.
THE CONDITION OF THIS BOND Is that If Principal:
Promptly makes payment to all claimants as defined In Section 255,05(1), Florida
Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly
by Principal In the prosecution of the work provided for In the Contract. then this bond is
void; otherwise it remains in full force.
Any changes in or under the Contract and compliance or noncompliance with any
formalities connected with the Contract or the changes do not affect Sureties obligation
under this Bond,
The provisions of this bond are subject to the time limitations of Section 255,05(2). In
no event will the Surety be liable in the aggregate to claimants for more than the penal
sum of this Payment Bond, regardless of the number of suits that may be filed by
claimants,
.
IN WITNESS WHEREOF, the above partJes have executed this instrument this ''''
day of December 2009, the name of each party being affixed and these presents
duly signed by its under-signed representative, pursuant to authority of its governing
body,
GC-CA-M
Signed, sealed and delivered
in the presence of:
PRINCIPAL
~~~
C~C-J
Mitchell & Stark Construction Co., Inc,
BY:
~
-"
Witnesses as to Principal
NAME: Brian Penner
ITS: CEO / VP
STATE OF Florida
COUNTY OF Collier
The foregoing instrument was acknowledged before me this I (.. day of Dec
20 09, by Brian Penner, as CEO I VP of Mitchell & Stark
Construction Co.. Inc , a Indiana corporation, on behalf of the
corporation, He/she is personallv known to me OR has produced as
identification and did (did not) take an oath,
My Commission Expires:
NOTARY l'UI\UC~TAT! Of fL(lllWA
.............. I:clinda Burgbacher
{ .l;t ',Co.llmi,sion # D D620455
"~./ EXvires: JAN, 22, 2011
soiID'iD 11:UlU '^TUN'flC OONDWQco..,1NC.
~~~
(Sig ure of Notary)
NAME:
(Legibly Printed)
Belinda Burabacher
(AFFIX OFFICIAL SEAL)
Notary Public. State of Florida
Commission No.: DD620455
ATTEST:
SURETY:
(Printed Name)
Fidelity & Deposit Comoanv of
Marvland
9229 Deleaates Row Ste 300
Indian olis Indiana 46240
(Bu' s d~ress
w~~
Stanley L. Williams
(Printed Name)
Robert E. Williams, Jr.
Attorney In Fact
GC-CA-A-2
The foregoing instrument was acknowledged before me this _ day of
, 2009, by , as
of
Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not)
~~ --~
Witnesses stanley L. Williams
,STATE OF
COUNTY OF
OR
Surety Company:
7L~l.
As Attorney in Fact r
(Attach Power of Attorney)
Robert E. Williams, Jr.
(Printed Name)
(Business Address)
(Telephone Number)
take an oath.
My Commission Expires:
(AFFIX OFFICIAL SEAL)
(Signature)
Name:
(legibly Printed)
Notary Public, State of:
Commission No,:
GC-CA-A-3
". ---~
EXHIBIT A
PUBLIC PERFORMANCE BOND
011 Well Road Widening. Segments 2 and 4A '/in fj
Bond No, P. _ _ 0 tY!
Contract No, 09-5287
KNOW ALL MEN BY THESE PRESENTS: That Mitchell & Stark Construction Co, Inc
as Principal, and Fidelity & DeDosit ComDanv of Maryland , as Surety,
located at 9229 Deleaates Row Suite 300, IndlanaDoiis. IN 46240
(Business Address) are held and firmly bound to The Board of County Commissioners
of Collier County Florida , as Obligee In the sum of Thirty-nine Million,
One Hundred EiQhty-four Thousand, Nine Hundred Ninety-nine Dollars and EiQhteen
Cents ($39,184,999,16) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns, jointly and severaily,
WHEREAS, Principal has entered into a contract dated as of the 'Ie day of
December , 2009, with Obligee for Oil Well Road
Seoment 2 and 4
in accordance with drawings and specifications, which contract is incorporated by
reference and made a part hereof, and Is referred to herein as the Contract.
THE CONDITION OF THIS BOND Is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract.
and
2, Pays Obligee any and all losses, damages, costs and attorneys' fees that
Obligee sustains because of any default by Principal under the Contract, including, but
not limited to, all delay damages, whether liquidated or actual, incurred by Obligee: and
3, Performs the guarantee of all work and materials furnished under the Contract for
the time specified in the Contract, then this bond is void; otherwise it remains in full
force, Any changes in or under the Contract and compliance or noncompliance with
any formalities connected with the Contract or the changes do not affect Sureties
obligation under this Bond,
The Surety, for value received, hereby stipulates and agrees that no changes.
extensions of time, alterations or additions to the terms of the Contract or other work to
be performed hereunder, or the specifications referred to therein shall in anywise affect
its obligations under this bond, and it does hereby waive notice of any such changes.
extensions of time, alterations or additions to the terms of the Contract or to work or to
the specifications,
This instrument shall be construed in all respects as a common law bond. It is
expressly understood that the time prOVisions and statute of limitations under Section
255,05, Florida Statutes, shall not apply to this bond,
GC-CA-A-4
In no event will the Surety be liable in the aggregate to Obligee for more than the penal
sum of this Performance Bond regardless of the number of suits that may be filed by
Obligee,
IN WITNESS WHEREOF, the above parties have executed this instrument this I""
day of December , 2009, the name of each party being affixed and these
presents duly signed by Its undersigned representative, pursuant to authority of its
governing body.
Signed, sealed and delivered
in the pr~ence of:
E:4f~
C~c- - C-->
Witnesses as to Principal
PRINCIPAL
Mitchell & Stark Construction Co,. Inc.
~
-
BY:
NAME: Brian Penner
ITS: CEONP
STATE OF Florida
COUNTY OF Collier
The foregoing
December
CEONP
Indiana
personallv known
instrument was acknowledged before me this ~ day of
, 2009, by Brian Penner , as
of Mitchell & Stark Const. Co.. Inc. a
corporation, on behalf of the corporation. He/she is
to me OR has produced
as identification and did
My Commission Expires:
take an oath,
~OTARY PCRl.JC. SHIT. OF FLORIDA
.......'...... Beiin~a Burgbacher
[ ~ ~ Commi"ioo # DD620455
<~,/ Expires: JA.'1. 22,2011
(Affl~ 'B'~~\~~AeS'EAi:.r
Name: Belinda Burqbacher
(Legibly Printed)
Notary Public, State of: Florida
Commission No.: 00620455
GC-CA-A-5
~
ATTEST:
SURETY:
Fidelity & Deposit Company of Maryland
(Printed Name)
9229 Delegates Row Ste 300
Indianapolis, Indiana 46240
(7~, ~
(Authorized Signature) (J..
~~-
Witnesses as to Surety
Stanley L. Williams
Robert E. Williams. Jr.
(Printed Name)
Atto e In Fact
Sur ompany:
Z 1 -an
OR
~~~.
Wltnesse Stanley L. Williams
A Attorney in Fact
(Attach Power of Attorney)
Robert E. Williams, Jr.
(Printed Name)
(Business Address)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this _ day of
, 2009, by , as
of
behalf of Surety,
. a Surety, on
He/She is personally known to me OR has produced
as Identification and who did (did not) take an oath.
My Commission Expires:
(Signature)
(AFFIX OFFICIAL SEAL)
Name:
(legibly Printed)
Notary Public, State of:
Commission No,:
GC-CA-A-6
Power of Attorney
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a
corporation of the State of Maryland, by WILLIAM J, MILLS, Vice President, and ERIC D, BARNES, Assistant Secretary,
in pursuance of authority granted by Article VI, Section 2, of the By,Laws of said Company, , are set forth on the
reverse side hereof and are hereby certified to be in full force and effect on the date h e by nominate, constitute
and appoint Robert E. WILLIAMS, JR., of Brown.town, Indiana, it orney,in-Fact, to
make, execute, seal and deliver, for, and on its behalf as sure e nds and
undertakings, and the execution of such bonds or u 0 . ~u S, shall be as binding upon said
Company, as fully and amply, tO~ll inte !'llt\ ~ , xecuted and acknowledged by the
regularly elected officers of the I\ils'bM~ , " In their own proper persons, ThiS power of attorney
revokes that Issued ~~' " 0 arch 4, 1998,
The said Assistant c at the extract set forth on the reverse side hereof IS a true copy of Article VI,
Section 2, of the By' 0 any, and IS now in force,
IN WITNESS W R OF, the said Vice, President and Assistant Secretary have hereunto subscribed thelT names and
affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 14th day of July, A.D,
2009,
ATTEST:
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
By:
/ l' J ;;,
/, ~I. (/lJ,)'
f,vl! !
!
L}J,~.
Eric D. Barnes
Assistant Secretary
William J Mills
Vice President
State of Maryland } ss:
City of Baltimore
On this 14th day of July, A,O, 2009, before the subscriber, a Notary Public of the State of Maryland, duly
commissioned and qualified, carne WILLIAM J, MILLS, Vice President, and ERIC D, BARNES, Assistant Secretary of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers
described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being
by me duly sworn, severally and each for himselfdeposeth and saith, that they are the said officers of the Company aforesaid,
and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal
and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of
the said Corporation.
IN TESTIMONY WHEREOF, I have hereunto set my hand and amxed my Omcial Seal the day and year first above
written.
,,\\'\\llllf//I
';~\~,~;:;I~,
""11;\,\\,1
~~ a O,A-vY'-Y'._
Constance A. Dunn Notary Public
My Commission Expires: July 14,201 I
POA,F 044,3937
"
-
EXTRACT FROM BY-LAWS OF FIDELITY AND DEPOSIT COMPANY OF MARYLAND
"Article VI, Section 2. The Chainnan of the Board, or the President, or any Executive Vice-President, or any of the Senior
Vice-Presidents or Vice-Presidents specially authorized so to do by the Board of Directors or by the Executive Committee,
shall have power, by and with the concurrence of the Secretary or anyone of the Assistant Secretaries, to appoint Resident
Vice-Presidents, Assistant Vice-Presidents and Attorneys-in-Fact as the business of the Company may require, or to
authorize any person or persons to execute on behalf of the Company any bonds, undertaking, recognizances, stipulations,
policies, contracts, agreements, deeds, and releases and assignments of judgements, decrees, mortgages and instruments in
the nature ofmortgages,...and to affix the seal of the Company thereto."
CERTIFICATE
I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certity
that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that
the Vice-President who executed the said Power of Attorney was one of the additional Vice-Presidents specially authorized
by the Board of Directors to appoint any Attorney-in-Fact as provided in Article VI, Section 2, of the By-Laws of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND.
This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the
Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on
the 10th day of May, 1990.
RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically
reproduced signature of any Vice-President, Secretary, or Assistant Secretary of the Company, whether made heretofore or
hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and
binding upon the Company with the same force and effect as though manually affixed."
IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company,
this
16th
day of December
2009
~-{, 11110
Assistant Secretary
ZURICH AMERICAN INbURANCE CO,JlPANY
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS, that the ZURICH AMERICAN INSURANCE COMPANY, a corporation created by and existing
under the laws of the State of New Yark does hereby nominate, constitute and appoint Robert E. WILLIAMS, JR., of Brownstown, Indiana,
its true and lawful Attorney-In-Fact with power and authority hereby conferred to sign, seal, and execute in its behalf, during the period
beginning with the date of issuance of this power,: any and all bonds and undertakings, recognizances ~r written obligations in
the nature thereof, and to bind ZURlCH AMERICAN INSURANCE COMPANY thereby, and ~ 1it)'u>Psaid AttorncYls),in,Fact
pursuant to these presents are hereby ratified and confirmed. This POW. cr of Attorney is ~~~~X~(' ursu and by the authority of
the following By-Law duly adopted by the Board of Directors of the Campan . ~~AJ'tr6t b dt~or-1.sscinded.
Article VI, Section 5. "...The President or a Vice President in a wr I t cHteste - ~ I. triA:ssistant Secretary may
appoint any person Attorney-ln.Fact with authorityjO e~ n s \'~~~~ l' 'any and other fonnal underwriting
contracts in reference thereto and reinsu~an ~~ts\rf1'a\fug to' . ,u~nd bonds of all kinds and attach the corporate
seal. Any such officers may revo~el1: 00 Jbti'tri ~ t.
This Power of Attorney is s~~le ~y . ifCrl~ y the authority of the following Resolution adopted by the Board of
Directors of the ZURICH Art:iiti'tleA~t\NB;' f~:GMPANY by unanimous consent in lieu of a special meeting dated December 15,
1998 ~' p \j-
'-J 1\, .~-'
" RESOLVED, that the slj1 &iJL6) the President or a Vice President and the attesting signature of a Secretary or an Assistant
Secretary and the seal of the Company may be affixed by facsimile on any Power of Attorney pursuant to Article VI. Section 5 of the
By-Laws, and the signature of a Secretary or an Assistant Secretary and the seal of the Company may be affixed by facsimile to any
certificate of any such power. Any such power or any certificate thereof with such facsimile signature and seal shall be valid and
binding on the Company. Furthermore, such power so executed, sealed and certified by certificate so executed and sealed shall. with
respect to any bond or undertaking to which it is attached, shall continue to be valid and binding on the Company."
IN WITNESS WHEREOF, the ZURICH AMERICAN INSURANCE COMPANY has caused these presents to be executed in its name and on
its behalf and its Corporate Seal to be hereunto affixed and attested by its officers thereunto duly authorized. this 14th day of July, A.D. 2009.
~..'''''.h.,
~.'~\NSv...'''''
~...~u ..._.... ~"lI.....
....~... ....~.
:I.lj ....."'o*"PO'f.t"..\o\
;~l~ ~.~t'C'-;
..0(. _._ :0:
=:r;: 10"
;'0\ 1_ j~=
0;."'3-: ". '"Ab~~
..~ ,,<...............~~ -~~..
~, * ",'
.....". .,~...
...... STATEOFMARYLAND}
ss:
CITY OF BALTIMORE Eric D. Barnes Secretary Frank E. Martin Jr. Vice Preside_~t
On the 14th day of July, A.D. 2009, before the subscriber. a Notary Public of the State of Maryland, duly commissioned and qualifiecl, Cal;1e
the above named Vice President and Secretary of ZURICH AMERICAN INSURANCE COMPANY, to me personally known to oe (he
individuals and officers described in and who executed the preceding instrument and they each acknowledged the execution of the salTl~ and
being by me duly sworn, they severally and each for himself deposed and said that they respectively hold the offices in said C;J.rplJraiion ~s
indicated, that the Seal affixed to the preceding instrument is the Corporate Seal of said Corporation. and that the said Corporate Sea], anu their
respective signature as such officers, were duly affixed and subscribed to the said instrument pursuant to all due corporate authorization.
IN WITNESS WHEREOF, I have herettnto set my hand and affixed my Official Seal the day and year first above,
ZURICH AMERICAN INSURANCE COMPANY
Y;A~ /) ~ /3cv+
~-j;.JJJ Z liut}
By:
,\,\,\'~_ll.~'I~""
r~\:i.J,;;:~1~;}
'11'<l11'"
~~vev>dC- C1 !,J,.u./'r.,-...~
Notary Public My Commission Expires: July 14, 2011
'Ibis Power of Attorney limits the acts of those named therein to the bonds and undertaking specifically named therein, and they have no
authority to bind the Company except in the manner and to the extent herein stated.
CERTIFICATE
I, the ondersigned, a Secretary of the ZURICH AMERICAN INSURANCE COMPANY, dn hereby certify that the foregning Power of
Attorney is still in full force and effect, and further certifY that Article VI, Section 5 of the By-Laws of the Company and the Resolution of the
Board of Directors set forth in said Power of Attorney arc still in force. _ ",~"'.'~.\N'S~".''''''
IN TESTIMONY WHEREOF I have hereto subscribed my name and affixed the seal of said Company /~~...~;~~:~1;t,...~
=~...~'" ~o\~'S
~t( -. - }8j
'~'" 1998 ,,' f.
~...""""... ..........ll:/
""< .......... ).~-.....
......... * ......>
""""II'.'.~
the 16th dayof December,. 2009
/1.. ,-
~!)~k , tlt-l-tA.-6
Gregory E. Murray
.')'ecretary
POA,Z ZA 044,3937
Serial Number: KE2009July14ZA 07/09ZA 044-3937
eRb~
PRODUCER
CERTIFICATE OF LIABILITY INSURANCE
OP 10 C2
MITCH-1 12/18
THIS CERTIFICATE IS ISSUEO AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER, THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW,
DATE (MM/DONYVY)
09
Tobias Insurance Group, Inc HQ
9247 N. Meridian St. Ste. 300
Indianapolis IN 46260
Phone:317-844-7759 Fax:317-844-9910
INSURERS AFFORDING COVERAGE
NAIC #
INSURED
INSURER A
INSURER 8
INSURERC
zur::ch Amer1-c"n Ins. Comp;ony
Arch~"~<:~"~:X,.I,:.~.~r....n.c~. .C~. ~
21199
Mitchell & Stark Construction
Company, Inc. - Florida
600~ Sfi~rley Street
Naples FL 3U09
COVERAGES
INSURER 0
INSURER E
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN IssueD TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS
NSR-\il<DD1:; --------
l TR NSRO TYPE OF INSURANCE POLICY NUMBER
GENERAL LIABILITY
POLICY-EFFECTIVE- pOLTey-~)tPlltUrO
DATE MMIDDIYYYY DATE MM/DDNYVY
LIMITS
AiX
X COMMERCIAL GENERAL LIABILITY
-- - -j CLAIMS MADE X OCCUR!
IX ! $5 ,OOO_l'roperty
~_~i~~:~~~~ TED~~;~~~~I~;!~~
1- POLICY X ~rgT ' LOC
AUTOMOBILE LIABILITY
X ANY AUTO
ALL OWNED AUTOS
SCHEDULED AUTOS
X HIRED AUTOS
,X_ i NON-OWNED AUTOS
I
1
GL0464148404(09)
03/01/09
03/01/10
I EACH OCCURRENCE 1$1,000,000
I-Oi'\JVIAGEl(JRrnTED -,-- -----j -~-----.-~-~---,--
~~g_~_occursn~_-i-!..~qo, OOQ.__~
I MED EXP (Anyone person) J $ 10,000
PERSONAL & ADV INJURY S 1,000,000 _
GENER~~AGGREG~TE $2,000,000
~~ODUCTS _ COMPE! AGG $ 2 , 0 0_0 ~O .2.9_
A
BAP464148304(09)
03/01/09 !
I COMBINED SINGLE LIMIT
03/01/10 ; (EaaCCldent)
,1,000,000
r-~--~-"----~--"--- ----
, BODILY INJURY
I {Per person)
~--
BODILY INJURY
(Per accident}
:$
PROPERTY DAMAGE
(Per accident)
: DEDUCTIBLE
!u_
AUTO ONLY. EA ACCIDENT $
EAACC $
AGG I ,
.:..'1_0.1 o.O()JIJOQ
'10,000,000
:$ -
"
S
GARAGE LIABILITY
; ANY AUTO
OTHER THAN
AUTO ONLY
EXCESS I UMBRELLA LIABILITY
B ix OCCUR r=-,]CLAIMSMADE ULP000476304
1---'
I
!
i EACH OCCURRENCE
03/01/09
03/01/10 : AGGREGATE
X RETENTION $ 0
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY Y I N
A ANY PROPRIETORIPARTNERIEXECUTlVO ' WC4 64148504 (09)
OFFICER/MEMBER EXCLUDED?
(MandatoryinNH) i
tfyes,deSCrlbSllnder I
SPECtAL PROVISIONS below
OTHER
03/01/09
ER
03/01/10 '1,000-,000.
_~~~ DISE~~..::~~_~_~?~!l,J!OO ,.Q.9JL__
EL DISEASE - POLICY LIMIT: $ 1,000,000
I
1
I
I
DESCRIPTION Of OPERA TlONS I LOCA TlONS / VEHICLES / EXCLUSIONS ADDEO BY ENDORSEMENT I SPECIAL PROVISIONS
ADDITIONAL INSURED(S) [GENERAL LIABILITY]: THE BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY & ANY OTHER CONTRACTUALLY REQUIRED ENTITIES BUT ONLY WITH
RESPECT TO OPERATIONS PERFORMED ON THEIR BEHALF BY OR FOR THE NAMED INSURED,
RE: OIL WELL ROAD SEGMENT 2 AND 4 BID, NO, 09-5287,
CERTIFICATE HOLDER
CANCELLATION
THE BOARD OF COUNTY
COMMISSIONERS COLLIER COUNTY
3301 TAMIAMI TRAIL
NAPLES FL 33962
SHOULD ANY Of THE ABOVE DESCRIBED POLICIES BE CANCELL.ED BEFORE THE EXPIRATION
COLLI _ 8 DATE THEREOf, THE ISSUING INSURER WILL ENDEAVOR TO MAIL ~_ DAYS WRITTEN
NOTICE TO THE CERTIfiCATE HOLDER NAMED TO THE LEfT, BUT fAILURE TO DO SO SHALL
IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
REPRESENTATIVES.
AUTHO 0 REPRESENTATIVE
ACORD 2S (2009/01)
II rights reserved.
NOTEP AD: INsURED'SNAME;';~~blici;].l r,Stli,!:'k Spnstruction D~II~C~;l
IF YOU ARE THE RECIPIENT OF THIS CERTIFICATE:
ANY WORDING TO INCLUDE THE HOLDER AS AN ADDITIONAL INSURED, PROVIDE
COVERAGE ON A PRIMARY AND NON-CONTRIBUTORY BASIS, OR PROVIDE A WAIVER OF
SUBROGATION APPLIES ONLY WHERE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT
IF YOU ARE THE REQUESTOR TO PROVIDE THIS CERTIFICATE:
Tobias Insurance Group, Inc. has, upon your request, issued the attached
Certificate of Insurance.
If you did not already, we highly recommend that you provide our Agency
with a copy of the insurance and indemnification provisions of the
contract pertaining to the certificate request so that we may properly
ascertain whether your insurance program addresses the terms, types and
amounts of insurance coverage referenced by the contract.
While most certificates can be issued at no cost to you, the contract may
identify insurance requirements that require the purchase of insurance
coverage at an additional premium. In some instances, the coverage
identified in the contract may be outside the underwriting guidelines of
the insurance carrier and cannot be obtained. In other instances, you may
not wish to purchase the additional coverage and may attempt to negotiate
changes in the insurance requirements.
In performing the review of your contracts, neither Tobias Insurance
Group, Inc. nor its employees are providing legal advice or a legal
opinion concerning any portion of the contract. Our Agency is not
undertaking to identify all potential liability that might arise under
this contract. This review is provided for your information and should
not be relied upon by third parties.
Any description of insurance coverage is subject to the terms, conditions,
exclusions and other provisions of the policies and any applicable
regulations, rating rules or plans.
EXHIBIT B
INSURANCE REQUIREMENTS
(1) The amounts and types of insurance coverage shall conform to the following minimum
requirements with the use of Insurance Services Office (ISO) forms and endorsements or their
equivalents, If Contractor has any self-insured retentions or deductibles under any of the below listed
minimum required coverages, Contractor must identify on the Certificate of Insurance the nature and
amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial
responsibility for such obligations. All self-insured retentions or deductibles will be Contractor's sole
responsibility.
(2) The insurance required by this Agreement shall be written for not less than the limits specified
herein or required by law, whichever is greater.
(3) Coverage's shall be maintained without interruption from the date of commencement of the
Work until the date of completion and acceptance of the Project by the Owner or as specified in this
Agreement, whichever is longer,
(4) Certificates of insurance (3 copies) acceptable to the Owner and in the form set forth in
Attachment I to this Exhibit B shall be filed with the Owner within ten (10) calendar days after Notice
of Award is received by Contractor evidencing the fact that Contractor has acquired and put in place
the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of
all insurance policies required shall be provided to Owner, on a timely basis, if requested by Owner.
(5) The Contractor and/or its insurance carrier shall provide 30 days written notice to the Owner of
policy cancellation or non-renewal on the part of the insurance carrier or the Contractor. Contractor
shall also notify Owner, in a like manner, within twenty-four (24) hours after receipt, of any notices of
expiration, cancellation, non-renewal or material change in coverages or limits received by Contractor
from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide
notice, In the event of a reduction in the aggregate limit of any policy to be provided by Contractor
hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full
extent permitted under such policy,
(6) All insurance coverage's of the Contractor shall be primary to any insurance or self insurance
program carried by the Owner applicable to this Project.
(7) The acceptance by Owner of any Certificate of Insurance does not constitute approval or
agreement by the Owner that the insurance requirements have been satisfied or that the insurance
policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement.
(8) Contractor shall require each of its Subcontractors to procure and maintain, until the
completion of the subcontractors work, insurance of the types and to the limits specified in this
Section unless such insurance requirements for the Subcontractor are expressly waived in writing by
the Owner.
(9) Should at any time the Contractor not maintain the insurance coverage's required herein, the
Owner may terminate the Agreement or at its sole discretion shall be authorized to purchase such
GC-CA-B-1
coverage's and charge the Contractor for such coverage's purchased. If Contractor fails to reimburse
Owner for such costs within thirty (30) days after demand, Owner has the right to offset these costs
from any amount due Contractor under this Agreement or any other agreement between Owner and
Contractor. The Owner shall be under no obligation to purchase such insurance, nor shall it be
responsible for the coverage's purchased or the insurance company or companies used. The
decision of the Owner to purchase such insurance coverage's shall in no way be construed to be a
waiver of any of its rights under the Contract Documents,
(10) If the initial or any subsequently issued Certificate of Insurance expires prior to the completion
of the Work or termination of the Agreement, the Contractor shall furnish to the Owner, renewal or
replacement Certificate(s) of Insurance not later than ten (10) calendar days after the date of their
expiration, Failure of the Contractor to provide the Owner with such renewal certificate(s) shall be
considered justification for the Owner to terminate the Agreement.
(11) All insurance policies required by this Agreement shall include the following provisions and
conditions by endorsement to the policies:
11,1 All insurance policies, other than the Business Automobile and Workers Compensation
policies, provided by Contractor to meet the requirements of this Agreement shall name
Collier County Government, Florida, as an additional insured as to the operations of
Contractor under this Agreement and shall contain a severability of interests provisions,
11,2, Companies issuing the insurance policy or policies shall have no recourse against
Owner for payment of premiums or assessments for any deductibles which all are at the
sole responsibility and risk of Contractor.
11,3, All insurance coverages of Contractor shall be primary to any insurance or self-
insurance program carried by Owner applicable to this Project, and the "Other
Insurance" provisions of any policies obtained by Contractor shall not apply to any
insurance or self-insurance program carried by Owner applicable to this Project.
11.4, The Certificates of Insurance, which are to be provided on the form set forth in
Attachment I to this Exhibit B, must identify the specific Project name, as well as the site
location and address (if any),
11,5, All insurance policies shall be fully performable in Collier County, Florida, and shall be
construed in accordance with the laws of the State of Florida.
WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY
Required by this Agreement? ~ Yes 0 No
(1) Workers' Compensation and Employers' Liability Insurance shall be maintained by the
Contractor during the term of this Agreement for all employees engaged in the work under this
Agreement in accordance with the laws of the State of Florida, The amounts of such insurance shall
not be less than:
a, Worker's Compensation - Florida Statutory Requirements
GC,CA-B-2
b, Employers' Liability
~ $1,000,000 Each Accident
$1,000,000 Disease Aggregate
$1,000,000 Disease Each Employee
(2) The insurance company shall waive all claims rights against the Owner and the policy shall be
so endorsed.
(3) United States Longshoreman's and HarbOlworker's Act coverage shall be maintained where
applicable to the completion of the work,
o Applicable ~ Not Applicable
(4) Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the
work.
o Applicable ~ Not Applicable
COMMERCIAL GENERAL LIABILITY
Required by this Agreement? ~ Yes 0 No
(1) Commercial General Liability Insurance shall be maintained by the Contractor on an
occurrence basis. Coverage will include, but not be limited to, Bodily Injury, Property Damage,
Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form
Property Damage including Completed Operations and Products and Completed Operations
Coverage. Limits of Liability shall not be less than the following:
x
General Aggregate
Products/Completed Operations Aggregate
Personal and Advertising Injury
Each Occurrence
Fire Damage
$2,000,000
$2,000,000
$2,000,000
$2,000,000
$ 50,000
(2) The General Aggregate Limit shall apply separately to this Project and the policy shall be
endorsed using the following endorsement wording, "This endorsement modifies insurance provided
under the following: Commercial General Liability Coverage Part. The General Aggregate Limit
under LIMITS OF INSURANCE applies separately to each of your projects away from premises
owned by or rented to you,"
(3) The Owner, Collier County Government, shall be named as an Additional Insured and the
policy shall be endorsed that such coverage shall be primary to any similar coverage carried by the
Owner.
(4) Coverage shall be included for explosion, collapse or underground property damage claims,
GC-CA-B-3
(5) Watercraft Liability coverage shall be carried at the limits shown above if applicable to the
completion of the work under this Agreement.
o Applicable r:g]Not Applicable
(6) Aircraft Liability coverage shall be carried at limits of $10,000,000 each occurrence if
applicable to the completion of the work under this Agreement.
o Applicable r:g] Not Applicable
PROPERTY INSURANCE - BUILDERS RISK
(1) The Owner may purchase and maintain in a company or companies lawfully authorized to do
business in the State of Florida and in Collier County, property insurance in the amount of the initial
Contract Amount as well as subsequent modifications thereto for the entire Work at the site on a
replacement cost basis without voluntary deductibles. Such property insurance shall be maintained,
unless otherwise provided in the Contract Documents or otherwise agreed in writing by all persons
and entities who are beneficiaries of such insurance, until final payment has been made or until no
person or entity other than the Owner has an insurable interest in the property required to be covered,
whichever is earlier. This insurance shall include interests of the Owner, the Contractor,
Subcontractors, Sub-subcontractors and Material Suppliers in the Work.
(2) Property insurance shall be on an all-risk policy form and, at the Owner's option, shall cover
reasonable compensation for Professional's services and expenses required as a result of such
insured loss, At the Owner's option, flood and windstorm insurance will also be purchased.
(3) The property insurance provided by the Owner requires minimum deductibles and the
Contractor shall pay costs not covered by the deductibles, The responsibility of the Contractor for
any deductible associated with the all-risk policy described above shall be limited to a maximum of
$5,000 for each occurrence unless higher deductibles are identified in Exhibit C of the Contract
Documents, The responsibility of the Contractor for any deductible associated with the flood or
windstorm insurance identified herein, if purchased by the Owner, shall be limited to a maximum of
$5,000 for each occurrence unless higher deductibles are identified in Exhibit C of the Contract
Documents,
(4) This property insurance shall cover portions of the Work stored off the site after written
approval of the Owner at the value established in the approval, and also portions of the Work in
transit.
(5) Boiler and Machinery Insurance, The Owner shall have the option of purchasing and
maintaining boiler and machinery insurance required by the Contract Documents or by law, which
shall specifically cover such insured objects during installation and until final acceptance by the
Owner. If purchased this insurance shall include interests of the Owner, Contractor, Subcontractors
and Sub-subcontractors in the Work,
(6) Waivers of Subrogation. The Owner and Contractor waive all rights against (1) each other and
any of their subcontractors, sub-subcontractors, agents and employees, each of the other, and (2) the
Design Professional, and Design Professional's subconsultants, for damages caused by fire or other
GC-CA-B-4
perils to the extent of insurance proceeds actually received by Owner under property insurance
obtained pursuant to this Exhibit or other any property insurance applicable to the Work, except such
rights as they have to proceeds of such insurance held by the Owner as fiduciary. The policies shall
provide waivers of subrogation by endorsement or otherwise,
(7) A loss insured under Owner's property insurance shall be adjusted by the Owner and made
payable to the Owner for the insured, as their interests may appear.
AUTOMOBILE LIABILITY INSURANCE
Required by this Agreement? [g] Yes D No
(1) Automobile Liability Insurance shall be maintained by the Contractor for the ownership,
maintenance or use of any owned, non-owned or hired vehicle with limits of not less than:
X Bodily Injury & Property Damage - $ 2,000,000
UMBRELLA LIABILITY
(1) Umbrella Liability may be maintained as part of the liability insurance of the Contractor and, if
so, shall be in addition to and in excess of any Employers' Liability, Commercial General Liability, and
Automobile Liability coverage's and shall include all coverage's on a "following form" basis,
(2) The policy shall contain wording to the effect that, in the event of the exhaustion of any
underlying coverage due to the payment of claims, the Umbrella policy will "drop down" to apply as
primary insurance,
GC-CA-B-5
EXHIBIT C
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER
STATE OF FLORIDA)
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) I n accordance with the Contract Documents and in consideration of $ paid,
("Contractor") releases and waives for itself and it's subcontractors,
material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort,
against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the
Agreement between Contractor and Owner dated 2009 for the period from
to , excluding all retainage withheld and any pending claims or
disputes as expressly specified as follows:
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges for
labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a
demand against any payment bond might be filed, have been fully satisfied and paid,
(3) To the maximum extent permitted by law, Contractor agrees to indemnify, defend and save harmless Owner from
all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the
performance by Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No,
CONTRACTOR
BY:
ITS:
President
DATE:
Witnesses
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this _ day of , 2009, by
,as of , a
corporation, on behalf of the corporation. He/she is personally known to me or has produced
as identification and did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commissioner No.:
GC-CA-C-1
EXHIBIT 0
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager)
(County Department)
Collier County Board of County Commissioners (the OWNER) or
Collier County Water-Sewer District (the OWNER)
Bid No,
Project No,
Application Date
FROM:
(Contractor's Representative) Payment Appiication No,
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE:
(Project Name)
%
%
Original Contract Price: $
Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
and stored to Date $
Less Retainage $
Total Earned Less Retainage $
Less previous payment (s) $
AMOUNT DUE THIS
APPLICATION: $
Original Contract Time:
Revised Contract Time:
Retainage @ 10% thru[insert date] $
Retainage @ _% after [insert date] $
=
Percent Work completed to Date:
Percent Contract Time completed to Date
Liquidated Damages to be Accrued $
Remaining Contract Balance $
ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through _ inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have
been paid for work which previous payments were issued and received from the OWNER and that current payment is now
due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and
CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that
has not been properly approved by Owner in writing and in advance of such Work,
By CONTRACTOR: (Contractor's Name)
(Signature) DATE:
(Type Name & Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional:
(DP's Name)
(Signature) DATE:
(Type Name & Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager:
(Signature) DATE:
(Type Name and Title)
GC-CA-D-1
ro
Wo "
...."''''' E
0
"'<(w "
I-~:I: " '"
0"''' "
I-I-!::: ~ ]!
ro
~;= ,,,, '"
12 .~
W ~ ..~
'" ~f-
~~ 11 ~ c
I~ . ~ E
. - ~
~
W !'. 0 (5
0:: c "
W ,Q "
U rn
'" ~ 0
'" ."
,. Z ~ "
a ~ "
~ c
W 00
0:: "
'" "
..~
WI ,,-
- c
0lJ) " ,-
z- ~'"
~ ~ .. ~
'"
<(0 ]!I~
!Dt- c ro
~ ,-
t-W ,,~
Zt- ;; ..
WW 1"8;:
0"" E ..
0::0. 8::
w:E
0.0 '" "
0 .- '"
filcw U ..
i'! c
...JI-Wt- _ 0
<(wO::c( c:;:;
I-...JOc 8E
e!i~o " ~
8~1- ~.E
- c ,
lJ) c c
~
0"" ~ E
w'" 0,2
~a; :;:; 0
t-W .. "
lJ)~ E,S
" 0 ..
. :Eo
. - 21
" c "~I
E ",0 ~f-
. <;
Ul Z ... i:~ '" "I
w u ~ f-W ",,s ,
. s 0 a. I
:J .0' '0 C ;::.!:
..J .t II . W ;:'"
<( .. t- ~ "
"
> W lJ)W ~-"!
-' zt-
u. a. 0'" ~~
0 :E _0
~w " ,-
W 0 'q
0 00
.... -z ro ..
"" ....- ._ .c
:J et: 0.lJ) " ..
C 0 a. 10~
W ;: '" W 0
J: lJ) t- c :
:J <( ~ ,-
U 00 -'=1 ~
Ul >:::> f- c
wo:: " ..
0:: I ~ ~
o.t- f- "
in'#-
c "
0 a~
W :.;:::; .....
.... W ..-
" 0
::> :J = Q)
0 .... 1.9 rn
W <(
" > <C'"
0 '" " .,;
lJ) ~~ ..
0-
.- 0 c
>- .~
d:1 ~ ii
Q; c .E
0
'" fJ "
c
~ E c
z '" - ..
0 c a~
i= E 'E u
a. :J= "
0: (f) ornE
0 -' " ,"
lJ) ~ o ro U
'iJ W 1; c c
0 0 ~;;;
" f- " 0. '"
" :5 m Q)
,!; ~ ~ c
" s '~I~
0 c,s
0 0_'"
;;1- ;; :.;:::; - ~
ro ~ f/j
E 0:: ~ ro ro
f- . W
Qj Z " !D I~ ~I~
u W " I
I . !:: ::> w_~
>< "0 z I.. .c 5:
W .t
N
,
o
<C
()
,
()
CJ
-c
~
o
"
~
III
ili
.;::
Q)
-
III
:!!
-c
l!!
o
-
r/)
o
1--
~:!
W C III
III C
ili-
!II
W
-c
"C .2
Q) ~
= Q)
ilia.
-
III III
C .-
.c
I-
"
00
o
[IJ
+ ~"C
~ ~ ~
30.__
E > III
l!! C
o a.
LL
-c
-c 0
CD 'C
> Q)
ro '; a..
~ .!a
a::~
'<=--c
III Q)
'" >
o .-
<( .- Q)
> "
Q) Q)
a: a::
C'")
o
<J:
o
(,
o
Q) ~
" Q)
,_ .c
o E
> '"
Cz
~
Q)
!
r/)
C
U 0
:;::;
Q) ,9
:J ~
,S "
C III
Q)
0 c
S
0
-
:0
:c
x
W
Q)
10
c
EXHIBIT E
CHANGE ORDER
TO:
Project Name:
Bid No,:
Change Order No,:
Change Order Description
FROM: Collier County Government
Construction Agreement Dated:
Date:
Original Agreement Amount "'."..,.."..,..,..,..,....".."....,..""'....--.."..$
Sum of previous Change Orders Amount ........__........................,....$
This Change Order Amount ......,....,............,...............,..................$
Revised Agreement Amount", '" ," ,.", ",., '" '" ",." "" ,', ",.,..""", ,."", $
Original Contract Time in calendar days
Adjusted number of calendar days due to previous Change Orders
This Change Order adjusted time is
Revised Contract Time in calendar days
Original Notice to Proceed Date
Completion date based on original Contract Time
Revised completion date
Contractor's acceptance of this Change Order shall constitute a modification to the Agreement
and will be performed subject to all the same terms and conditions as contained in the
Agreement, as if the same were repeated in this acceptance, The adjustments, if any, to the
Agreement shall constitute a full and final settlement of any and all claims of the Contractor
arising out of, or related to, the change set forth herein, including claims for impact and delay
costs,
Prepared by: Date:
Project Manager
Recommended by:
Design Professional
Date:
Accepted by:
Date:
Contractor
Approved by:
Approved by:
Date:
Department Director
Date:
Division Administrator
Approved by:
Date:
Purchasing Department
Authorized by
Director
Date:
(For use by Owner: Fund
Number: )
Cost Center:
Object Code:
Project
GC-CA-E-5
EXHIBIT F
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No,
Design Professional's Project No,
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the
following specified parts thereof:
To
OWNER
And
To
Substantial Completion is the state in the progress of the Work when the Work (or designated
portion) is sufficiently complete in accordance with the Contract Documents so that the Owner
can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has
been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN
PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the
requirements of the Contract Documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto, This list may not be all-inclusive,
and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all
the Work in accordance with the Contract Documents, The items in the tentative list shall be completed
or corrected by CONTRACTOR within days of the above date of Substantial Completion,
GC,CA,F-1
The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance,
heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the
Contract Documents,
Executed by Design Professional on
,2009
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
,2009
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
,2009
OWNER
By:
Type Name and Title
GC-CA-F-2
Bid No,: Project No,:
Contractor:
The following items have been secured by the
for the Project known as
EXHIBIT G
FINAL PAYMENT CHECKLIST
Date:
,2009
and have been reviewed and found to comply with the requirements of the Contract Documents,
Original Contract Amount: Final Contract Amount:
Commencement Date:
Substantial Completion Time as set forth in the Agreement: Calendar Days,
Actual Date of Substantial Completion:
Final Completion Time as set forth in the Agreement: Calendar Days,
Actual Final Completion Date:
YES NO
1, All Punch List items completed on
2, Warranties and Guarantees assigned to Owner (attach to this form),
3, Effective date of General one year warranty from Contractor is:
4, 2 copies of Operation and Maintenance manuals for equipment and
system submitted (list manuais in attachment to this form),
5, As-Built drawings obtained and dated:
6, Owner personnel trained on system and equipment operation,
7, Certificate of Occupancy No,:
issued on (attach to this form),
8, Certificate of Substantial Completion issued on
9, Final Payment Application and Affidavits received from Contractor on:
10, Consent of Surety received on
11, Operating Department personnel notified Project is in operating phase,
12, All Spare Parts or Special Tools provided to Owner:
13, Finished Floor Elevation Certificate provided to Owner:
14, Other:
If NO is checked for any of the above, attach
If any of the above is not applicable, indicate by N/A.
explanation,
Acknowledgments:
By Contractor:
(Company Name)
(Signature)
(Typed Name & Title)
By Design
Professional:
(Firm Name)
(Signature)
(Typed Name & Title)
(Department Name)
(Signature)
(Name & Title)
By Owner:
GC-CA-G-1
EXHIBIT H
GENERAL TERMS AND CONDITIONS
1. INTENT OF CONTRACT DOCUMENTS.
1.1 It is the intent of the Contract Documents to describe a functionally complete
Project (or portion thereof) to be constructed in accordance with the Contract
Documents, Any work, materials or equipment that may reasonably be inferred from
the Contract Documents as being required to produce the intended result shall be
supplied whether or not specifically called for. When words which have a well known
technical or trade meaning are used to describe work, materials or equipment, such
words shall be interpreted in accordance with that meaning. Reference to standard
specifications, manuals or codes of any technical society, organization or association or
to the laws or regulations of any governmental authority having jurisdiction over the
Project, whether such reference be specific or by implication, shall mean the latest
standard specification, manual, code, law or regulation in effect at the time the Work is
performed, except as may be otherwise specifically stated herein,
1,2 If before or during the performance of the Work Contractor discovers a conflict,
error or discrepancy in the Contract Documents, Contractor immediately shall report
same to the Project Manager in writing and before proceeding with the Work affected
thereby shall obtain a written interpretation or clarification from the Project Manager;
said interpretation or clarification from the Project Manager may require Contractor to
consult directly with Design Professional or some other third party, as directed by
Project Manager. Contractor shall take field measurements and verify field conditions
and shall carefully compare such field measurements and conditions and other
information known to Contractor with the Contract Documents before commencing any
portion of the Work,
1,3 Drawings are intended to show general arrangements, design and extent of Work
and are not intended to serve as shop drawings. Specifications are separated into
divisions for convenience of reference only and shall not be interpreted as establishing
divisions for the Work, trades, subcontracts, or extent of any part of the Work, In the
event of a discrepancy between or among the drawings, specifications or other Contract
Document provisions, Contractor shall be required to comply with the provision which is
the more restrictive or stringent requirement upon the Contractor, as determined by the
Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws,
fittings, fillers, hardware, accessories, trim and other parts required in connection with
any portion of the Work to make a complete, serviceable, finished and first quality
installation shall be furnished and installed as part of the Work, whether or not called for
by the Contract Documents,
2. INVESTIGATION AND UTILITIES.
2.1 Subject to Section 2,3 below, Contractor shall have the sole responsibility of
satisfying itself concerning the nature and location of the Work and the general and
local conditions, and particularly, but without limitation, with respect to the following:
GC-CA,H-1
those affecting transportation, access, disposal, handling and storage of materials;
availability and quality of labor; water and electric power; availability and condition of
roads; work area; living facilities; climatic conditions and seasons; physical conditions at
the work-site and the project area as a whole; topography and ground surface
conditions; nature and quantity of the surface materials to be encountered; subsurface
conditions; equipment and facilities needed preliminary to and during performance of
the Work; and all other costs associated with such performance, The failure of
Contractor to acquaint itself with any applicable conditions shall not relieve Contractor
from any of its responsibilities to perform under the Contract Documents, nor shall it be
considered the basis for any claim for additional time or compensation,
2,2 Contractor shall locate all existing roadways, railways, drainage facilities and
utility services above, upon, or under the Project site, said roadways, railways, drainage
facilities and utilities being referred to in this Sub-Section 2,2 as the "Utilities".
Contractor shall contact the owners of all Utilities to determine the necessity for
relocating or temporarily interrupting any Utilities during the construction of the Project.
Contractor shall schedule and coordinate its Work around any such relocation or
temporary service interruption, Contractor shall be responsible for properly shoring,
supporting and protecting all Utilities at all times during the course of the Work, The
Contractor is responsible for coordinating all other utility work so as to not interfere with
the prosecution of the Work (except those utilities to be coordinated by the Owner as
may be expressly described elsewhere in the Contract Documents),
2,3 Notwithstanding anything in the Contract Documents to the contrary, if conditions
are encountered at the Project site which are (i) subsurface or otherwise concealed
physical conditions which differ materially from those indicated in the Contract
Documents or (ii) unknown physical conditions of an unusual nature, which differ
materially from those ordinarily found to exist and generally recognized as inherent in
construction activities of the character provided for in the Contract Documents, and
which reasonably should not have been discovered by Contractor as part of its scope of
site investigative services required pursuant to the terms of the Contract Documents,
then Contractor shall provide Owner with prompt written notice thereof before conditions
are disturbed and in no event later than three (3) calendar days after first observance of
such conditions. Owner and Design Professional shall promptly investigate such
conditions and, if they differ materially and cause an increase or decrease in
Contractor's cost of, or time required for, performance of any part of the Work, Owner
will acknowledge and agree to an equitable adjustment to Contractor's compensation or
time for performance, or both, for such Work. If Owner determines that the conditions at
the site are not materially different from those indicated in the Contract Documents or
not of an unusual nature or should have been discovered by Contractor as part of its
investigative services, and that no change in the terms of the Agreement is justified,
Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in
opposition to such determination by Owner must be made within seven (7) calendar
days after Contractor's receipt of Owner's written determination notice, If Owner and
Contractor cannot agree on an adjustment to Contractor's cost or time of performance,
the dispute resolution procedure set forth in the Contract Documents shall be complied
with by the parties,
GC-CA-H-2
3. SCHEDULE.
3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award,
shall prepare and submit to Project Manager, for their review and approval, a progress
schedule for the Project (herein "Progress Schedule"), The Progress Schedule shall
relate to all Work required by the Contract Documents, and shall utilize the Critical Path
method of scheduling and shall provide for expeditious and practicable execution of the
Work within the Contract Time, The Progress Schedule shall indicate the dates for
starting and completing the various stages of the Work,
3,2 The Progress Schedule shall be updated monthly by the Contractor. All monthly
updates to the Progress Schedule shall be subject to the Project Manager's review and
approval. Contractor shall submit the updates to the Progress Schedule with its
monthly Applications for Payment noted below. The Project Manager's review and
approval of the submitted Progress Schedule updates shall be a condition precedent to
the Owner's obligation to pay Contractor.
3.3 All work under this Agreement shall be performed in accordance with the
requirements of all Collier County Noise Ordinances then in effect. Unless otherwise
specified, work will generally be limited to the hours of 7:00 a,m. to 5:00 p,m., Monday
through Friday, No work shall be performed outside the specified hours without the
prior approval of the Project Manager.
4. PROGRESS PAYMENTS.
4,1 Prior to submitting its first monthly Application for Payment, Contractor shall
submit to Project Manager, for their review and approval, a schedule of values based
upon the Contract Price, listing the major elements of the Work and the dollar value for
each element. After its approval by the Project Manager, this schedule of values shall
be used as the basis for the Contractor's monthly Applications for Payment. This
schedule shall be updated and submitted each month along with a completed copy of
the Application for Payment form signed by the Contractor's authorized representative
and attached to the Agreement as Exhibit D.
4,2 Prior to submitting its first monthly Application for Payment, Contractor shall
provide to the Project Manager the list of its Subcontractors and materialmen submitted
with its Bid showing the work and materials involved and the dollar amount of each
subcontract and purchase order. Contractor acknowledges and agrees that any
modifications to the list of Subcontractors submitted with Contractor's Bid and any
subsequently identified Subcontractors are subject to Owner's prior written approval.
The first Application for Payment shall be submitted no earlier than thirty (30) days after
the Commencement Date, Notwithstanding anything herein to the contrary, if approved
by Owner in its sole discretion, Contractor may submit its invoice for any required
Payment and Performance Bonds prior to the first Application of Payment provided that
Contractor has furnished Owner certified copies of the receipts evidencing the premium
paid by Contractor for the bonds,
GC-CA-H,3
4,3 Unless expressly approved by Owner in advance and in writing, said approval at
Owner's sole discretion, Owner is not required to make any payment for materials or
equipment that have not been incorporated into the Project. If payment is requested on
the basis of materials and equipment not incorporated into the Project, but delivered
and suitably stored at the site or at another location, and such payment and storage
have been agreed to by Owner in writing, the Application for Payment also shall be
accompanied by a bill of sale, invoice or other documentation warranting that the Owner
has received the materials and equipment free and clear of all liens, charges, security
interests and encumbrances, together with evidence that the materials and equipment
are covered by appropriate property insurance and other arrangements to protect
Owner's interest therein, all of which shall be subject to the Owner's satisfaction,
Thereafter, with each Application for Payment, Contractor also shall complete and
submit to Owner as part of its Application for Payment, the Stored Materials Record
attached hereto and made a part hereof as Exhibit D,
4.4 Contractor shall submit six (6) copies of its monthly Application for Payment to
the Project Manager or his or her designee, as directed by Owner (which designee may
include the Design Professional), After the date of each Application for Payment is
stamped as received and within the timeframes set forth in Section 218.735 F,S" the
Project Manager, or Design Professional, shall either: (1) Indicate its approval of the
requested payment; (2) indicate its approval of only a portion of the requested payment,
stating in writing its reasons therefore; or (3) return the Application for Payment to the
Contractor indicating, in writing, the reason for refusing to approve payment. Payments
of proper invoices in the amounts approved shall be processed and paid in accordance
with Section 218,735, F,S, and the administrative procedures established by the
County's Purchasing Department and the Clerk of Court's Finance Department
respectively,
In the event of a total denial by Owner and return of the Application for Payment by the
Project Manager, the Contractor may make the necessary corrections and re-submit the
Application for Payment. The Owner shall, within ten (10) business days after the
Application for Payment is stamped and received and after Project Manager approval of
an Application for Payment, pay the Contractor the amounts so approved,
4,5 Owner shall retain ten percent (10%) of the gross amount of each monthly
payment request or ten percent (10%) of the portion thereof approved by the Project
Manager for payment, whichever is less, Such sum shall be accumulated and not
released to Contractor until final payment is due unless othelWise agreed to by the
Owner in accordance with Florida Statute 255,078. The Project Manager shall have the
discretion to establish, in writing, a schedule to periodically reduce the percentage of
cumulative retainage held through out the course of the Project schedule, Owner shall
reduce the amount of the retainage withheld on each payment request subsequent to
fifty percent (50%) completion subject to the guidelines set forth in Florida Statute
255,078 and as set forth in the Owner's Purchasing Policy,
4,6 Monthly payments to Contractor shall in no way imply approval or acceptance of
Contractor's Work.
GC-CA-H-4
4,7 Each Application for Payment, subsequent to the first pay application, shall be
accompanied by a Release and Affidavit, in the form attached as Exhibit C,
acknowledging Contractor's receipt of payment in full for all materials, labor, equipment
and other bills that are then due and payable by Owner with respect to the current
Application for Payment. Further, to the extent directed by Owner and in Owner's sole
discretion, Contractor shall also submit a Release and Affidavit from each
Subcontractor, sub-subcontractor, or supplier in the form attached as Exhibit C
acknowledging that each Subcontractor, sub-subcontractor or supplier has been paid in
full through the previous month's Application for Payment. The Owner shall not be
required to make payment until and unless these affidavits are furnished by Contractor.
4.8 Contractor agrees and understands that funding limitations exist and that the
expenditure of funds must be spread over the duration of the Project at regular intervals
based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting
its first monthly Application for Payment, Contractor shall prepare and submit for Project
Manager's review and approval, a detailed Project Funding Schedule, which shall be
updated as necessary and approved by Owner to reflect approved adjustments to the
Contract Amount and Contract Time, No voluntary acceleration or early completion of
the Work shall modify the time of payments to Contractor as set forth in the approved
Project Funding Schedule,
4.9 Notwithstanding anything in the Contract Documents to the contrary, Contractor
acknowledges and agrees that in the event of a dispute concerning payments for Work
performed under this Agreement, Contractor shall continue to perform the Work
required of it under this Agreement pending resolution of the dispute provided that
Owner continues to pay Contractor all amounts that Owner does not dispute are due
and payable,
5. PAYMENTS WITHHELD.
5.1 The Project Manager may decline to approve any Application for Payment, or
portions thereof, because of subsequently discovered evidence or subsequent
inspections that reveal non-compliance with the Contract Documents, The Project
Manager may nullify the whole or any part of any approval for payment previously
issued and Owner may withhold any payments otherwise due Contractor under this
Agreement or any other agreement between Owner and Contractor, to such extent as
may be necessary in the Owner's opinion to protect it from loss because of:
(a) defective Work not remedied; (b) third party claims filed or reasonable evidence
indicating probable filing of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt
that the Work can be completed for the unpaid balance of the Contract Amount; (e)
reasonable indication that the Work will not be completed within the Contract Time; (f)
unsatisfactory prosecution of the Work by the Contractor; or (g) any other material
breach of the Contract Documents by Contractor,
GC-CA,H-5
5,2 If any conditions described in 5,1, are not remedied or removed, Owner may,
after three (3) days written notice, rectify the same at Contractor's expense, Provided,
however, in the event of an emergency, Owner shall not be required to provide
Contractor any written notice prior to rectifying the situation at Contractor's expense,
Owner also may offset against any sums due Contractor the amount of any liquidated or
non-liquidated obligations of Contractor to Owner, whether relating to or arising out of
this Agreement or any other agreement between Contractor and Owner.
6. FINAL PAYMENT.
6.1 Owner shall make final payment to Contractor in accordance with Section
218,735, F,S, and the administrative procedures established by the County's
Purchasing Department and the Clerk of Court's Finance Department after the Work is
finally inspected and accepted by Project Manager as set forth with Section 20,1 herein,
provided that Contractor first, and as an explicit condition precedent to the accrual of
Contractor's right to final payment, shall have furnished Owner with a properly executed
and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly
executed copy of the Surety's consent to final payment and such other documentation
that may be required by the Contract Documents and the Owner. Prior to release of
final payment and final retainage, the Contractor's Representative and the Project
Manager shall jointly complete the Final Payment Checklist, a representative copy of
which is attached to this Agreement as Exhibit G,
6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and
all claims by Contractor against Owner arising out of this Agreement or otherwise
relating to the Project, except those previously made in writing in accordance with the
requirements of the Contract Documents and identified by Contractor as unsettled in its
final Application for Payment. Neither the acceptance of the Work nor payment by
Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of
Contractor hereunder or to the recovery of damages for defective Work not discovered
by the Design Professional or Project Manager at the time of final inspection.
7. SUBMITTALS AND SUBSTITUTIONS.
7,1 Contractor shall carefully examine the Contract Documents for all requirements
for approval of materials to be submitted such as shop drawings, data, test results,
schedules and samples, Contractor shall submit all such materials at its own expense
and in such form as required by the Contract Documents in sufficient time to prevent
any delay in the delivery of such materials and the installation thereof,
7,2 Whenever materials or equipment are specified or described in the Contract
Documents by using the name of a proprietary item or the name of a particular supplier,
the naming of the item is intended to establish the type, function and quality required,
Unless the name is followed by words indicating that no substitution is permitted,
materials or equipment of other suppliers may be accepted by Owner if sufficient
information is submitted by Contractor to allow the Owner to determine that the material
or equipment proposed is equivalent or equal to that named, Requests for review of
GC-CA-H-6
substitute items of material and equipment will not be accepted by Owner from anyone
other than Contractor and all such requests must be submitted by Contractor to Project
Manager within thirty (30) calendar days after Notice of Award is received by
Contractor, unless otherwise mutually agreed in writing by Owner and Contractor.
7,3 If Contractor wishes to furnish or use a substitute item of material or equipment,
Contractor shall make application to the Project Manager for acceptance thereof,
certifying that the proposed substitute shall adequately perform the functions and
achieve the results called for by the general design, be similar and of equal substance
to that specified and be suited to the same use as that specified. The application shall
state that the evaluation and acceptance of the proposed substitute will not prejudice
Contractor's achievement of substantial completion on time, whether or not acceptance
of the substitute for use in the Work will require a change in any of the Contract
Documents (or in the provisions of any other direct contract with Owner for the Project)
to adapt the design to the proposed substitute and whether or not incorporation or use
by the substitute in connection with the Work is subject to payment of any license fee or
royalty, All variations of the proposed substitute from that specified will be identified in
the application and available maintenance, repair and replacement service shall be
indicated. The application also shall contain an itemized estimate of all costs that will
result directly or indirectly from acceptance of such substitute, including costs for
redesign and claims of other contractors affected by the resulting change, all of which
shall be considered by the Project Manager in evaluating the proposed substitute. The
Project Manager may require Contractor to furnish at Contractor's expense additional
data about the proposed substitute,
7.4 If a specific means, method, technique, sequence or procedure of construction is
indicated in or required by the Contract Documents, Contractor may furnish or utilize a
substitute means, method, sequence, technique or procedure of construction
acceptable to the Project Manager, if Contractor submits sufficient information to allow
the Project Manager to determine that the substitute proposed is equivalent to that
indicated or required by the Contract Documents, The procedures for submission to
and review by the Project Manager shall be the same as those provided herein for
substitute materials and equipment.
7,5 The Project Manager shall be allowed a reasonable time within which to evaluate
each proposed substitute and, if need be, to consult with the Design Professional. No
substitute will be ordered, installed or utilized without the Project Manager's prior written
acceptance which shall be evidenced by a Change Order, a Work Directive Change, a
Field Order or an approved Shop Drawing, The Owner may require Contractor to
furnish at Contractor's expense a special performance guarantee or other surety with
respect to any substitute. The Project Manager will record time required by the Project
Manager and the Project Manager's consultants in evaluating substitutions proposed by
Contractor and making changes in the Contract Documents occasioned thereby,
Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse
Owner for the charges of the Design Professional and the Design Professional's
consultants for evaluating each proposed substitute.
GC,CA-H-7
8. DAILY REPORTS, AS-BUlL TS AND MEETINGS.
8,1 Unless waived in writing by Owner, Contractor shall complete and submit to
Project Manager on a weekly basis a daily log of the Contractor's work for the preceding
week in a format approved by the Project Manager. The daily log shall document all
activities of Contractor at the Project site including, but not limited to, the following:
8,1,1 Weather conditions showing the high and low temperatures during
work hours, the amount of precipitation received on the Project site, and any other
weather conditions which adversely affect the Work;
8.1,2
Soil conditions which adversely affect the Work;
The hours of operation by Contractor's and Sub-Contractor's
8,1,3
personnel;
8.1.4 The number of Contractor's and Sub-Contractor's personnel present
and working at the Project site, by subcontract and trade;
8,1,5 All equipment present at the Project site, description of equipment use
and designation of time equipment was used (specifically indicating any down time);
8.1.6 Description of Work being performed at the Project site;
8,1,7 Any unusual or special occurrences at the Project site;
8.1,8 Materials received at the Project site;
8,1,9 A list of all visitors to the Project
8,1,10 Any problems that might impact either the cost or quality of the Work or
the time of performance,
The daily log shall not constitute nor take the place of any notice required to be given by
Contractor to Owner pursuant to the Contract Documents,
8,2 Contractor shall maintain in a safe place at the Project site one record copy of
the Contract Documents, including, but not limited to, all drawings, specifications,
addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as
well as all written interpretations and clarifications issued by the Design Professional, in
good order and annotated to show all changes made during construction. The
annotated drawings shall be continuously updated by the Contractor throughout the
prosecution of the Work to accurately reflect all field changes that are made to adapt the
Work to field conditions, changes resulting from Change Orders, Work Directive
Changes and Field Orders, and all concealed and buried installations of piping, conduit
and utility services, All buried and concealed items, both inside and outside the Project
site, shall be accurately located on the annotated drawings as to depth and in
relationship to not less than two (2) permanent features (e,g. interior or exterior wall
GC-CA-H-8
faces), The annotated drawings shall be clean and all changes, corrections and
dimensions shall be given in a neat and legible manner in a contrasting color. The
"As-Built" record documents, together with all approved samples and a counterpart of all
approved shop drawings shall be available to the Project Manager or Design
Professional for reference, Upon completion of the Work and as a condition precedent
to Contractor's entitlement to final payment, these "As-Built" record documents, samples
and shop drawings shall be delivered to Project Manager by Contractor for Owner.
8,3 Contractor shall keep all records and supporting documentation which concern or
relate to the Work hereunder for a minimum of five (5) years from the date of
termination of this Agreement or the date the Project is completed or such longer period
as may be required by law, whichever is later. Owner, or any duly authorized agents or
representatives of Owner, shall have the right to audit, inspect and copy all such
records and documentation as often as they deem necessary during the period of this
Agreement and during the document retention period noted above; provided, however,
such activity shall be conducted only during normal business hours,
9. CONTRACT TIME AND TIME EXTENSIONS.
9.1 Contractor shall diligently pursue the completion of the Work and coordinate the
Work being done on the Project by its subcontractors and material-men, as well as
coordinating its Work with all work of others at the Project Site, so that its Work or the
work of others shall not be delayed or impaired by any act or omission by Contractor.
Contractor shall be solely responsible for all construction means, methods, techniques,
sequences, and procedures, as well as coordination of all portions of the Work under
the Contract Documents, and the coordination of Owner's suppliers and contractors as
set forth in Paragraph 12,2. herein,
9.2 Should Contractor be obstructed or delayed in the prosecution of or completion
of the Work as a result of unforeseeable causes beyond the control of Contractor, and
not due to its fault or neglect, including but not restricted to acts of Nature or of the
public enemy, acts of government, fires, floods, epidemics, quarantine regulation,
strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48)
hours after the commencement of such delay, stating the cause or causes thereof, or be
deemed to have waived any right which Contractor may have had to request a time
extension,
9,3 No interruption, interference, inefficiency, suspension or delay in the
commencement or progress of the Work from any cause whatever, including those for
which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty
to perform or give rise to any right to damages or additional compensation from Owner.
Contractor expressly acknowledges and agrees that it shall receive no damages for
delay. Contractor's sole remedy, if any, against Owner will be the right to seek an
extension to the Contract Time; provided, however, the granting of any such time
extension shall not be a condition precedent to the aforementioned "No Damage For
Delay" provision, This paragraph shall expressly apply to claims for early completion,
as well as to claims based on late completion.
GC,CA-H-9
9.4 In no event shall any approval by Owner authorizing Contractor to continue
performing Work under this Agreement or any payment issued by Owner to Contractor
be deemed a waiver of any right or claim Owner may have against Contractor for delay
damages hereunder.
10. CHANGES IN THE WORK.
10.1 Owner shall have the right at any time during the progress of the Work to
increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit an itemized estimate of any cost or time increases or savings it foresees as
a result of the change, Except in an emergency endangering life or property, or as
expressly set forth herein, no addition or changes to the Work shall be made except
upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of
Owner is authorized to direct any extra or changed work orally, Any alleged changes
must be approved by Owner in writing prior to starting such items. Owner will not be
responsible for the costs of any changes commenced without Owner's express prior
written approval. Failure to obtain such prior written approval for any changes will be
deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by
Contractor that such items are in fact not a change but rather are part of the Work
required of Contractor hereunder,
10,2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be
issued and executed promptly after an agreement is reached between Contractor and
Owner concerning the requested changes, Contractor shall promptly perform changes
authorized by duly executed Change Orders, The Contract Amount and Contract Time
shall be adjusted in the Change Order in the manner as Owner and Contractor shall
mutually agree.
10.3 If Owner and Contractor are unable to agree on a Change Order for the
requested change, Contractor shall, nevertheless, promptly perform the change as
directed by Owner in a written Work Directive Change. In that event, the Contract
Amount and Contract Time shall be adjusted as directed by Owner. If Contractor
disagrees with the Owner's adjustment determination, Contractor must make a claim
pursuant to Section 11 of these General Conditions or else be deemed to have waived
any claim on this matter it might otherwise have had,
10,4 In the event a requested change results in an increase to the Contract Amount,
the amount of the increase shall be limited to the Contractor's reasonable direct labor
and material costs and reasonable actual equipment costs as a result of the change
(including allowance for labor burden costs) plus a maximum ten percent (10%) markup
for all overhead and profit. In the event such change Work is performed by a
Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all
Subcontractors' and sub-subcontractors' direct labor and material costs and actual
equipment costs shall be permitted, with a maximum five percent (5%) markup thereon
by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen
percent (15%), All compensation due Contractor and any Subcontractor or
GC-CA-H-10
sub-subcontractor for field and home office overhead is included in the markups noted
above. Contractor's and Sub-Contractor's bond costs associated with any change order
shall be included in the overhead and profit expenses and shall not be paid as a
separate line item.
10,5 Owner shall have the right to conduct an audit of Contractor's books and records
to verify the accuracy of the Contractor's claim with respect to Contractor's costs
associated with any Change Order or Work Directive Change,
10,6 The Project Manager shall have authority to order minor changes in the Work not
involving an adjustment to the Contract Amount or an extension to the Contract Time
and not inconsistent with the intent of the Contract Documents, Such changes may be
effected by Field Order or by other written order. Such changes shall be binding on the
Contractor.
10.7 Any modifications to this Contract shall be in compliance with the County
Purchasing Policy and Administrative Procedures in effect at the time such
modifications are authorized.
11. CLAIMS AND DISPUTES.
11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or
interpretation of the terms of the Contract Documents, payment of money, extension of
time or other relief with respect to the terms of the Contract Documents. The term
"Claim" also includes other disputes and matters in question between Owner and
Contractor arising out of or relating to the Contract Documents. The responsibility to
substantiate a Claim shall rest with the party making the Claim.
11,2 Claims by the Contractor shall be made in writing to the Project Manager within
forty-eight (48) hours from when the Contractor knew or should have known of the event
giving rise to such Claim or else the Contractor shall be deemed to have waived the
Claim, Written supporting data shall be submitted to the Project Manager within fifteen
(15) calendar days after the occurrence of the event, unless the Owner grants additional
time in writing, or else the Contractor shall be deemed to have waived the Claim. All
Claims shall be priced in accordance with the provisions of Subsection 10,4.
11,3 The Contractor shall proceed diligently with its performance as directed by the
Owner, regardless of any pending Claim, action, suit or administrative proceeding,
unless otherwise agreed to by the Owner in writing, Owner shall continue to make
payments in accordance with the Contract Documents during the pendency of any
Claim,
12. OTHER WORK.
12,1 Owner may perform other work related to the Project at the site by Owner's own
forces, have other work performed by utility owners or let other direct contracts, If the
fact that such other work is to be performed is not noted in the Contract Documents,
written notice thereof will be given to Contractor prior to starting any such other work, If
GC,CA-H-11
Contractor believes that such performance will involve additional expense to Contractor
or require additional time, Contractor shall send written notice of that fact to Owner and
Design Professional within forty-eight (48) hours of being notified of the other work, If
the Contractor fails to send the above required forty-eight (48) hour notice, the
Contractor will be deemed to have waived any rights it otherwise may have had to seek
an extension to the Contract Time or adjustment to the Contract Amount.
12.2 Contractor shall afford each utility owner and other contractor who is a party to
such a direct contract (or Owner, if Owner is performing the additional work with
Owner's employees) proper and safe access to the site and a reasonable opportunity
for the introduction and storage of materials and equipment and the execution of such
work and shall properly connect and coordinate its Work with theirs. Contractor shall do
all cutting, fitting and patching of the Work that may be required to make its several
parts come together properly and integrate with such other work, Contractor shall not
endanger any work of others by cutting, excavating or otherwise altering their work and
will only cut or alter their work with the written consent of the Project Manager and the
others whose work will be affected. The duties and responsibilities of Contractor under
this paragraph are for the benefit of such utility owners and other Contractors to the
extent that there are comparable provisions for the benefit of Contractor in said direct
contracts between Owner and such utility owners and other contractors,
12,3 If any part of Contractor's Work depends for proper execution or results upon the
work of any other contractor or utility owner (or Owner), Contractor shall inspect and
promptly report to Project Manager in writing any delays, defects or deficiencies in such
work that render it unavailable or unsuitable for such proper execution and results,
Contractor's failure to report will constitute an acceptance of the other work as fit and
proper for integration with Contractor's Work,
13. INDEMNIFICATION AND INSURANCE.
13.1 To the maximum extent permitted by Florida law, Contractor shall indemnify and
hold harmless Owner and its officers and employees from any and all liabilities, claims,
damages, penalties, demands, judgments, actions, proceedings, losses or costs,
including, but not limited to, reasonable attorneys' fees and paralegals' fees, whether
resulting from any claimed breach of this Agreement by Contractor or from personal
injury, property damage, direct or consequential damages, or economic loss, to the
extent caused by the negligence, recklessness, or intentional wrongful misconduct of
Contractor or anyone employed or utilized by the Contractor in the performance of this
Agreement.
13,2 The duty to defend under this Article 13 is independent and separate from the
duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the
Contractor, Owner and any indemnified party, The duty to defend arises immediately
upon presentation of a claim by any party and written notice of such claim being
provided to Contractor. Contractor's obligation to indemnify and defend under this
Article 13 will survive the expiration or earlier termination of this Agreement until it is
determined by final judgment that an action against the Owner or an indemnified partyn
GC-CA-H-12
for the matter indemnified hereunder is fully and finally barred by the applicable statute
of limitations.
13.3 Contractor shall obtain and carry, at all times during its performance under the
Contract Documents, insurance of the types and in the amounts set forth in Exhibit B to
the Agreement. Further, the Contractor shall at all times comply with all of the terms,
conditions, requirements and obligations set forth under Exhibit B,
14. COMPLIANCE WITH LAWS.
14.1 Contractor agrees to comply, at its own expense, with all federal, state and local
laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the
Project, including but not limited to those dealing with taxation, worker's compensation,
equal employment and safety (including, but not limited to, the Trench Safety Act,
Chapter 553, Florida Statutes), If Contractor observes that the Contract Documents are
at variance therewith, it shall promptly notify Project Manager in writing. To the extent
any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain
terms in this Agreement in order for this Agreement to be enforceable, such terms shall
be deemed included in this Agreement. Notwithstanding anything in the Contract
Documents to the contrary, it is understood and agreed that in the event of a change in
any applicable laws, ordinances, rules or regulations subsequent to the date this
Agreement was executed that increases the Contractor's time or cost of performance of
the Work, Contractor is entitled to a Change Order for such increases, except to the
extent Contractor knew or should have known of such changes prior to the date of this
Agreement.
14,2 By executing and entering into this agreement, the Contractor is formally
acknowledging without exception or stipulation that it is fully responsible for complying
with the provisions of the Immigration Reform and Control Act of 1986 as located at 8
U.S,C. 1324, et sea, and regulations relating thereto, as either may be amended,
Failure by the Contractor to comply with the laws referenced herein shall constitute a
breach of this agreement and the County shall have the discretion to unilaterally
terminate this agreement immediately,
15. CLEANUP AND PROTECTIONS.
15,1 Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work, At the completion of the Work, Contractor
shall remove all debris, rubbish and waste materials from and about the Project site, as
well as all tools, appliances, construction equipment and machinery and surplus
materials, and shall leave the Project site clean and ready for occupancy by Owner.
15.2 Any existing surface or subsurface improvements, including, but not limited to,
pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery,
not indicated in the Contract Documents to be removed or altered, shall be protected by
Contractor from damage during the prosecution of the Work, Subject to the Section 2,3
GC,CA-H-13
above, any such improvements so damaged shall be restored by Contractor to the
condition equal to that existing at the time of Contractor's commencement of the Work,
16. ASSIGNMENT.
16,1 Contractor shall not assign this Agreement or any part thereof, without the prior
consent in writing of Owner. Any attempt to assign or otherwise transfer this Agreement,
or any part herein, without the Owner's consent, shall be void. If Contractor does, with
approval, assign this Agreement or any part thereof, it shall require that its assignee be
bound to it and to assume toward Contractor all of the obligations and responsibilities
that Contractor has assumed toward Owner.
17. PERMITS, LICENSES AND TAXES.
17.1 Pursuant to Section 218.80, F,S., Owner will pay for all Collier County permits
and fees, including license fees, permit fees, impact fees or inspection fees applicable
to the Work through an internal budget transfer(s). Contractor is not responsible for
paying for permits issued by Collier County, but Contractor is responsible for acquiring
all permits. Owner may require the Contractor to deliver internal budget transfer
documents to applicable Collier County agencies when the Contractor is acquiring
permits,
17,2 All permits, fees and licenses necessary for the prosecution of the Work which
are not issued by Collier County shall be acquired and paid for by the Contractor.
17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the
Work,
18. TERMINATION FOR DEFAULT.
18,1 Contractor shall be considered in material default of the Agreement and such
default shall be considered cause for Owner to terminate the Agreement, in whole or in
part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under
the Contract Documents within the time specified herein; or (2) fails to properly and
timely perform the Work as directed by the Project Manager or as provided for in the
approved Progress Schedule; or (3) performs the Work unsuitably or neglects or
refuses to remove materials or to correct or replace such Work as may be rejected as
unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails
to resume Work which has been suspended within a reasonable time after being
notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act
of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more
than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to
obey any applicable codes, laws, ordinances, rules or regulations with respect to the
Work; or (10) materially breaches any other provision of the Contract Documents,
18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner
determines that Contractor has not remedied and cured the default(s) within seven (7)
GC-CA-H-14
calendar days following receipt by Contractor of said written notice or such longer
period of time as may be consented to by Owner in writing and in its sole discretion,
then Owner, at its option, without releasing or waiving its rights and remedies against
the Contractor's sureties and without prejudice to any other right or remedy it may be
entitled to hereunder or by law, may terminate Contractor's right to proceed under the
Agreement, in whole or in part, and take possession of all or any portion of the Work
and any materials, tools, equipment, and appliances of Contractor, take assignments of
any of Contractor's subcontracts and purchase orders, and complete all or any portion
of Contractor's Work by whatever means, method or agency which Owner, in its sole
discretion, may choose,
18,3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that
it shall not be entitled to receive any further payments hereunder until after the Project is
completed. All moneys expended and all of the costs, losses, damages and extra
expenses, including all management, administrative and other overhead and other
direct and indirect expenses (including Design Professional and attorneys' fees) or
damages incurred by Owner incident to such completion, shall be deducted from the
Contract Amount, and if such expenditures exceed the unpaid balance of the Contract
Amount, Contractor agrees to pay promptly to Owner on demand the full amount of
such excess, including costs of collection, attorneys' fees (including appeals) and
interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of
the Contract Amount exceeds all such costs, expenditures and damages incurred by the
Owner to complete the Work, such excess shall be paid to the Contractor. The amount
to be paid to the Contractor or Owner, as the case may be, shall be approved by the
Project Manager, upon application, and this obligation for payment shall survive
termination of the Agreement.
18.4 The liability of Contractor hereunder shall extend to and include the full amount of
any and all sums paid, expenses and losses incurred, damages sustained, and
obligations assumed by Owner in good faith under the belief that such payments or
assumptions were necessary or required, in completing the Work and providing labor,
materials, equipment, supplies, and other items therefore or re-letting the Work, and in
settlement, discharge or compromise of any claims, demands, suits, and judgments
pertaining to or arising out of the Work hereunder.
18.5 If, after notice of termination of Contractor's right to proceed pursuant to this
Section, it is determined for any reason that Contractor was not in default, or that its
default was excusable, or that Owner is not entitled to the remedies against Contractor
provided herein, then the termination will be deemed a termination for convenience and
Contractor's remedies against Owner shall be the same as and limited to those afforded
Contractor under Section 19 below,
18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within
thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill
some material obligation owed by Owner to Contractor under this Agreement, and
(ii) Owner has failed to cure such default within fourteen (14) days of receiving written
notice of same from Contractor, then Contractor may stop its performance under this
GC-CA-H-15
Agreement until such default is cured, after giving Owner a second fourteen (14) days
written notice of Contractor's intention to stop performance under the Agreement. If the
Work is so stopped for a period of one hundred and twenty (120) consecutive days
through no act or fault of the Contractor or its Subcontractors or their agents or
employees or any other persons performing portions of the Work under contract with the
Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving
written notice to Owner of Contractor's intent to terminate this Agreement. If Owner
does not cure its default within fourteen (14) days after receipt of Contractor's written
notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner,
terminate the Agreement and recover from the Owner payment for Work performed
through the termination date, but in no event shall Contractor be entitled to payment for
Work not performed or any other damages from Owner.
19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION.
19.1 Owner shall have the right to terminate this Agreement without cause upon
seven (7) calendar days written notice to Contractor. In the event of such termination
for convenience, Contractor's recovery against Owner shall be limited to that portion of
the Contract Amount eamed through the date of termination, together with any
retainage withheld and reasonable termination expenses incurred, but Contractor shall
not be entitled to any other or further recovery against Owner, including, but not limited
to, damages or any anticipated profit on portions of the Work not performed.
19,2 Owner shall have the right to suspend all or any portions of the Work upon giving
Contractor not less than two (2) calendar days' prior written notice of such suspension,
If all or any portion of the Work is so suspended, Contractor's sole and exclusive
remedy shall be to seek an extension of time to its schedule in accordance with the
procedures set forth in the Contract Documents, In no event shall the Contractor be
entitled to any additional compensation or damages, Provided, however, if the ordered
suspension exceeds six (6) months, the Contractor shall have the right to terminate the
Agreement with respect to that portion of the Work which is subject to the ordered
suspension,
20. COMPLETION.
20,1 When the entire Work (or any portion thereof designated in writing by Owner) is
ready for its intended use, Contractor shall notify Project Manager in writing that the
entire Work (or such designated portion) is substantially complete, Within a reasonable
time thereafter, Owner, Contractor and Design Professional shall make an inspection of
the Work (or designated portion thereof) to determine the status of completion. If
Owner, after conferring with the Design Professional, does not consider the Work (or
designated portion) substantially complete, Project Manager shall notify Contractor in
writing giving the reasons therefore. If Owner, after conferring with the Design
Professional, considers the Work (or designated portion) substantially complete, Project
Manager shall prepare and deliver to Contractor a Certificate of Substantial Completion
which shall fix the date of Substantial Completion for the entire Work (or designated
portion thereof) and include a tentative punch-list of items to be completed or corrected
GC-CA-H-16
by Contractor before final payment. Owner shall have the right to exclude Contractor
from the Work and Project site (or designated portion thereof) after the date of
Substantial Completion, but Owner shall allow Contractor reasonable access to
complete or correct items on the tentative punch-list.
20,2 Upon receipt of written certification by Contractor that the Work is completed in
accordance with the Contract Documents and is ready for final inspection and
acceptance, Project Manager and Design Professional will make such inspection and, if
they find the Work acceptable and fully performed under the Contract Documents shall
promptly issue a final Certificate for Payment, recommending that, on the basis of their
observations and inspections, and the Contractor's certification that the Work has been
completed in accordance with the terms and conditions of the Contract Documents, that
the entire balance found to be due Contractor is due and payable, Neither the final
payment nor the retainage shall become due and payable until Contractor submits:
(1) Receipt of Contractor's Final Application for Payment.
(2) The Release and Affidavit in the form attached as Exhibit C.
(3) Consent of surety to final payment.
(4) Receipt of the final payment check list.
(5) If required by Owner, other data establishing payment or satisfaction of all
obligations, such as receipts, releases and waivers of liens, arising out of
the Contract Documents, to the extent and in such form as may be
designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination
as to the Work's acceptability, even though the Design Professional may have issued its
recommendations, Unless and until the Owner is completely satisfied, neither the final
payment nor the retainage shall become due and payable,
21. WARRANTY.
21.1 Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any subcontractor or materialmen supplying
materials, equipment or fixtures to be incorporated into the Project. Contractor warrants
to Owner that any materials and equipment furnished under the Contract Documents
shall be new unless otherwise specified, and that all Work shall be of good quality, free
from all defects and in conformance with the Contract Documents, Contractor further
warrants to Owner that all materials and equipment furnished under the Contract
Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers,
fabricators, suppliers or processors except as otherwise provided for in the Contract
Documents, If, within one (1) year after Substantial Completion, any Work is found to
be defective or not in conformance with the Contract Documents, Contractor shall
correct it promptly after receipt of written notice from Owner. Contractor shall also be
responsible for and pay for replacement or repair of adjacent materials or Work which
may be damaged as a result of such replacement or repair. Further, in the event of an
emergency, Owner may commence to correct any defective Work, without prior notice
GC-CA-H-17
to Contractor, at Contractor's expense. These warranties are in addition to those
implied warranties to which Owner is entitled as a matter of law,
21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or
another representative of the Owner, shall conduct an inspection of the warranted work
to verify compliance with the requirements of the Agreement. The Contractor's
Representative shall be present at the time of inspection and shall take remedial actions
to correct any deficiencies noted in the inspection. Failure of the Contractor to correct
the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from
future bid opportunities with the Owner, in addition to any other rights and remedies
available to Owner.
22. TESTS AND INSPECTIONS.
22.1 Owner, Design Professional, their respective representatives, agents and
employees, and governmental agencies with jurisdiction over the Project shall have
access at all times to the Work, whether the Work is being performed on or off of the
Project site, for their observation, inspection and testing, Contractor shall provide
proper, safe conditions for such access, Contractor shall provide Project Manager with
timely notice of readiness of the Work for all required inspections, tests or approvals,
22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of
any public authority having jurisdiction over the Project requires any portion of the Work
to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish Project
Manager the required certificates of inspection, testing or approval. All inspections,
tests or approvals shall be performed in a manner and by organizations acceptable to
the Project Manager.
22.3 Contractor is responsible, without reimbursement from Owner, for re-inspection
fees and costs; to the extent such re-inspections are due to the fault or neglect of
Contractor.
22.4 If any Work that is to be inspected, tested or approved is covered without written
concurrence from the Project Manager, such work must, if requested by Project
Manager, be uncovered for observation, Such uncovering shall be at Contractor's
expense unless Contractor has given Project Manager timely notice of Contractor's
intention to cover the same and Project Manager has not acted with reasonable
promptness to respond to such notice. If any Work is covered contrary to written
directions from Project Manager, such Work must, if requested by Project Manager, be
uncovered for Project Manager's observation and be replaced at Contractor's sole
expense,
22,5 The Owner shall charge to Contractor and may deduct from any payments due
Contractor all engineering and inspection expenses incurred by Owner in connection
with any overtime work. Such overtime work consisting of any work during the
GC,CA-H-18
construction period beyond the regular eight (8) hour day and for any work performed
on Saturday, Sunday or holidays,
22,6 Neither observations nor other actions by the Project Manager or Design
Professional nor inspections, tests or approvals by others shall relieve Contractor from
Contractor's obligations to perform the Work in accordance with the Contract
Documents.
23. DEFECTIVE WORK.
23.1 Work not conforming to the requirements of the Contract Documents or any
warranties made or assigned by Contractor to Owner shall be deemed defective Work,
If required by Project Manager, Contractor shall as directed, either correct all defective
Work, whether or not fabricated, installed or completed, or if the defective Work has
been rejected by Project Manager, remove it from the site and replace it with non-
defective Work, Contractor shall bear all direct, indirect and consequential costs of
such correction or removal (including, but not limited to fees and charges of engineers,
architects, attorneys and other professionals) made necessary thereby, and shall hold
Owner harmless for same,
23,2 If the Project Manager considers it necessary or advisable that covered Work be
observed by Design Professional or inspected or tested by others and such Work is not
otherwise required to be inspected or tested, Contractor, at Project Manager's request,
shall uncover, expose or otherwise make available for observation, inspection or tests
as Project Manager may require, that portion of the Work in question, furnishing all
necessary labor, material and equipment. If it is found that such Work is defective,
Contractor shall bear all direct, indirect and consequential costs of such uncovering,
exposure, observation, inspection and testing and of satisfactory reconstruction
(including, but not limited to, fees and charges of engineers, architects, attorneys and
other professionals), and Owner shall be entitled to an appropriate decrease in the
Contract Amount. If, however, such Work is not found to be defective, Contractor shall
be allowed an increase in the Contract Amount and/or an extension to the Contract
Time, directly attributable to such uncovering, exposure, observation, inspection, testing
and reconstruction,
23,3 If any portion of the Work is defective, or if Contractor fails to supply sufficient
skilled workers, suitable materials or equipment or fails to finish or perform the Work in
such a way that the completed Work will conform to the Contract Documents, Project
Manager may order Contractor to stop the Work, or any portion thereof, until the cause
for such order has been eliminated, The right of Project Manager to stop the Work
shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be
construed as obligating the Project Manager to exercise this right for the benefit of
Design Engineer, Contractor, or any other person,
23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest
to accept defective Work, the Owner may do so, Contractor shall bear all direct, indirect
GC-CA-H-19
and consequential costs attributable to the Owner's evaluation of and determination to
accept defective Work, If such determination is rendered prior to final payment, a
Change Order shall be executed evidencing such acceptance of such defective Work,
incorporating the necessary revisions in the Contract Documents and reflecting an
appropriate decrease in the Contract Amount. If the Owner accepts such defective
Work after final payment, Contractor shall promptly pay Owner an appropriate amount
to adequately compensate Owner for its acceptance of the defective Work,
23.5 If Contractor fails, within a reasonable time after the written notice from Project
Manager, to correct defective Work or to remove and replace rejected defective Work
as required by Project Manager or Owner, or if Contractor fails to perform the Work in
accordance with the Contract Documents, or if Contractor fails to comply with any of the
provisions of the Contract Documents, Owner may, after seven (7) days written notice
to Contractor, correct and remedy any such deficiency, Provided, however, Owner shall
not be required to give notice to Contractor in the event of an emergency, To the extent
necessary to complete corrective and remedial action, Owner may exclude Contractor
from any or all of the Project site, take possession of all or any part of the Work, and
suspend Contractor's seNices related thereto, take possession of Contractor's tools,
appliances, construction equipment and machinery at the Project site and incorporate in
the Work all materials and equipment stored at the Project site or for which Owner has
paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design
Professional and their respective representatives, agents, and employees such access
to the Project site as may be necessary to enable Owner to exercise the rights and
remedies under this paragraph, All direct, indirect and consequential costs of Owner in
exercising such rights and remedies shall be charged against Contractor, and a Change
Order shall be issued, incorporating the necessary revisions to the Contract Documents,
including an appropriate decrease to the Contract Amount. Such direct, indirect and
consequential costs shall include, but not be limited to, fees and charges of engineers,
architects, attorneys and other professionals, all court costs and all costs of repair and
replacement of work of others destroyed or damaged by correction, removal or
replacement of Contractor's defective Work. Contractor shall not be allowed an
extension of the Contract Time because of any delay in performance of the Work
attributable to the exercise by Owner of Owner's rights and remedies hereunder.
24. SUPERVISION AND SUPERINTENDENTS.
24.1 Contractor shall plan, organize, supeNise, schedule, monitor, direct and control
the Work competently and efficiently, devoting such attention thereto and applying such
skills and expertise as may be necessary to perform the Work in accordance with the
Contract Documents, Contractor shall be responsible to see that the finished Work
complies accurately with the Contract Documents. Contractor shall keep on the Work at
all times during its progress a competent resident superintendent, who shall be subject
to Owner's approval and not be replaced Without prior written notice to Project Manager
except under extraordinary circumstances, The superintendent shall be employed by
the Contractor and be the Contractor's representative at the Project site and shall have
authority to act on behalf of Contractor. All communications given to the superintendent
shall be as binding as if given to the Contractor. Owner shall have the right to direct
GC-CA-H-20
Contractor to remove and replace its Project superintendent, with or without cause.
Attached to the Agreement as Exhibit N is a list identifying Contractor's Project
Superintendent and all of Contractor's key personnel who are assigned to the Project;
such identified personnel shall not be removed without Owner's prior written approval,
and if so removed must be immediately replaced with a person acceptable to Owner.
24,2 Contractor shall have a competent superintendent on the project at all times
whenever contractor's work crews, or work crews of other parties authorized by the
Project Manager are engaged in any activity whatsoever associated with the Project.
Should the Contractor fail to comply with the above condition, the Project Manager
shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient
moneys to account for the Owner's loss of adequate project supervision, not as a
penalty, but as liquidated damages, separate from the liquidated damages described in
Section 5,8, for services not rendered,
25. PROTECTION OF WORK.
25.1 Contractor shall fully protect the Work from loss or damage and shall bear the
cost of any such loss or damage until final payment has been made, If Contractor or
anyone for whom Contractor is legally liable for is responsible for any loss or damage
to the Work, or other work or materials of Owner or Owner's separate contractors,
Contractor shall be charged with the same, and any moneys necessary to replace such
loss or damage shall be deducted from any amounts due Contractor.
25,2 Contractor shall not load nor permit any part of any structure to be loaded in any
manner that will endanger the structure, nor shall Contractor subject any part of the
Work or adjacent property to stresses or pressures that will endanger it.
25.3 Contractor shall not disturb any benchmark established by the Owner or Design
Professional with respect to the Project. If Contractor, or its subcontractors, agents or
anyone for whom Contractor is legally liable, disturbs the Owner or Design
Professional's benchmarks, Contractor shall immediately notify Project Manager and
Design Professional. The Owner or Design Professional shall re-establish the
benchmarks and Contractor shall be liable for all costs incurred by Owner associated
therewith,
26. EMERGENCIES.
26,1 In the event of an emergency affecting the safety or protection of persons or the
Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner or Design Professional is obligated to act to
prevent threatened damage, injury or loss, Contractor shall give Project Manager
written notice within forty-eight (48) hours after Contractor knew or should have known
of the occurrence of the emergency, if Contractor believes that any significant changes
in the Work or variations from the Contract Documents have been caused thereby, If
the Project Manager determines that a change in the Contract Documents is required
because of the action taken in response to an emergency, a Change Order shall be
GC-CA-H-21
issued to document the consequences of the changes or variations, If Contractor fails
to provide the forty-eight (48) hour written notice noted above, the Contractor shall be
deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time,
27. USE OF PREMISES.
27,1 Contractor shall maintain all construction equipment, the storage of materials and
equipment and the operations of workers to the Project site and land and areas
identified in and permitted by the Contract Documents and other lands and areas
permitted by law, rights of way, permits and easements, and shall not unreasonably
encumber the Project site with construction equipment or other material or equipment.
Contractor shall assume full responsibility for any damage to any such land or area, or
to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from
the performance of the Work,
28. SAFETY.
28,1 Contractor shall be responsible for initiating, maintaining and supervising all
safety precautions and programs in connection with the Work, Contractor shall take all
necessary precautions for the safety of, and shall provide the necessary protection to
prevent damage, injury or loss to:
28,1,1 All employees on or about the project site and other persons and/or
organizations who may be affected thereby;
28,1,2 All the Work and materials and equipment to be incorporated therein,
whether in storage on or off the Project site; and
28,1.3 Other property on Project site or adjacent thereto, including trees,
shrubs, walks, pavements, roadways, structures, utilities and any underground
structures or improvements not designated for removal, relocation or replacement in the
Contract Documents.
28,2 Contractor shall comply with all applicable codes, laws, ordinances, rules and
regulations of any public body having jurisdiction for the safety of persons or property or
to protect them from damage, injury or loss, Contractor shall erect and maintain all
necessary safeguards for such safety and protection, Contractor shall notify owners of
adjacent property and of underground structures and improvements and utility owners
when prosecution of the Work may affect them, and shall cooperate with them in the
protection, removal, relocation or replacement of their property, Contractor's duties and
responsibilities for the safety and protection of the Work shall continue until such time
as the Work is completed and final acceptance of same by Owner has occurred,
28,3, Contractor shall designate a responsible representative located on a full time
basis at the Project site whose duty shall be the prevention of accidents, This person
shall be Contractor's superintendent unless otherwise designated in writing by
Contractor to Owner.
GC-CA-H,22
28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner
property. All employees of Contractor, as well as those of all subcontractors and those
of any other person or entity for whom Contractor is legally liable (collectively referred to
herein as "Employees"), shall not possess or be under the influence of any such
substances while on any Owner property, Further, Employees shall not bring on to any
Owner property any gun, rifle or other firearm, or explosives of any kind.
28,5 Contractor acknowledges that the Work may be progressing on a Project site
which is located upon or adjacent to an existing Owner facility, In such event,
Contractor shall comply with the following:
28,5,1
All Owner facilities are smoke free. Smoking is strictly prohibited;
28.5,2 All Employees shall be provided an identification badge by
Contractor. Such identification badge must be prominently displayed on the outside of
the Employees' clothing at all times, All Employees working at the Project site must log
in and out with the Contractor each day;
28,5.3 Contractor shall strictly limit its operations to the designated work
areas and shall not permit any Employees to enter any other portions of Owner's
property without Owner's expressed prior written consent;
28.5.4 All Employees are prohibited from distributing any papers or other
materials upon Owner's property, and are strictly prohibited from using any of Owner's
telephones or other office equipment;
28,5,5 All Employees shall at all times comply with the OSHA regulations
with respect to dress and conduct at the Project site, Further, all Employees shall
comply with the dress, conduct and facility regulations issued by Owner's officials
onsite, as said regulations may be changed from time to time;
28,5,6 All Employees shall enter and leave Owner's facilities only through
the ingress and egress points identified in the site utilization plan approved by Owner or
as otherwise designated, from time to time, by Owner in writing;
28,5.7 When requested, Contractor shall cooperate with any ongoing
Owner investigation involving personal injury, economic loss or damage to Owner's
facilities or personal property therein;
28,5,8 The Employees may not solicit, distribute or sell products while on
Owner's property, Friends, family members or other visitors of the Employees are not
permitted on Owner's property; and
28,5,9 At all times, Contractor shall adhere to Owner's safety and security
regulations, and shall comply with all security requirements at Owner's facilities, as said
regulations and requirements may be modified or changed by Owner from time to time,
GC,CA,H-23
29. PROJECT MEETINGS.
Prior to the commencement of Work, the Contractor shall attend a pre-construction
conference with the Project Manager, Design Professional and others as appropriate to
discuss the Progress Schedule, procedures for handling shop drawings and other
submittals, and for processing Applications for Payment, and to establish a working
understanding among the parties as to the Work. During the prosecution of the Work,
the Contractor shall attend any and all meetings convened by the Project Manager with
respect to the Project, when directed to do so by Project Manager or Design
Professional. The Contractor shall have its subcontractors and suppliers attend all such
meetings (including the pre-construction conference) as may be directed by the Project
Manager.
30. VENDOR PERFORMANCE EVALUATION
Owner has implemented a Vendor Performance Evaluation System for all contracts
awarded in excess of $25,000, To this end, vendors will be evaluated on their
performance upon completion/termination of this Agreement.
31. MAINTENANCE OF TRAFFIC POLICY
For all projects that are conducted within a Collier County Right-of-Way, the Contractor
shall provide and erect Traffic Control Devices as prescribed in the current edition of the
Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local
roadways and as prescribed in the Florida Department of Transportations Design
Standards (DS), where applicable on state roadways. These projects shall also comply
with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by
reference, Copies are available through Risk Management and/or Purchasing
Departments, and on-line at colliergov,neUpurchasing,
The Contractor will be responsible for obtaining copies of all required manuals, MUTCD,
FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to
become familiar with their requirements, Strict adherence to the requirements of the
Maintenance of Traffic ("MOT") policy will be enforced under this Contract.
All costs associated with the Maintenance of Traffic shall be included on the line item on
the bid page, If MOT is required, MOT is to be provided within ten (10) days of receipt
of Notice of Award,
32. SALES TAX SAVINGS AND DIRECT PURCHASE
32,1 Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the
Work, No markup shall be applied to sales tax, Additionally, as directed by Owner and
at no additional cost to Owner, Contractor shall comply with and fully implement the
sales tax savings program with respect to the Work, as set forth in section 32,2 below:
GC-CA-H-24
32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from
sales tax and may wish to generate sales tax savings for the Project, Owner reserves
the right to make direct purchases of various construction materials and equipment
included in the Work ("Direct Purchase"), Contractor shall prepare purchase orders to
vendors selected by Contractor, for execution by Owner, on forms provided by Owner.
Contractor shall allow two weeks for execution of all such purchase orders by Owner.
Contractor represents and warrants that it will use its best efforts to cooperate with
Owner in implementing this sales tax savings program in order to maximize cost
savings for the Project. Adjustments to the Contract Amount will be made by
appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the
saved sales taxes. A Change Order shall be processed promptly after each Direct
Purchase, or group of similar or related Direct Purchases, unless otherwise mutually
agreed upon between Owner and Contractor. With respect to all Direct Purchases by
Owner, Contractor shall remain responsible for coordinating, ordering, inspecting,
accepting delivery, storing, handling, installing, warranting and quality control for all
Direct Purchases. Notwithstanding anything herein to the contrary, Contractor
expressly acknowledges and agrees that all Direct Purchases shall be included within
and covered by Contractor's warranty to Owner to the same extent as all other
warranties provided by Contractor pursuant to the terms of the Contract Documents, In
the event Owner makes a demand against Contractor with respect to any Direct
Purchase and Contractor wishes to make claim against the manufacturer or supplier of
such Direct Purchase, upon request from Contractor Owner shall assign to Contractor
any and all warranties and Contract rights Owner may have from any manufacturer or
supplier of any such Direct Purchase by Owner.
32,3 Bidder represents and warrants that it is aware of its statutory responsibilities for
sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal
excise taxes,
33. SUBCONTRACTS
33.1 Contractor shall review the design and shall determine how it desires to divide
the sequence of construction activities, Contractor will determine the breakdown and
composition of bid packages for award of subcontracts, based on the current Project
Milestone Schedule, and shall supply a copy of that breakdown and composition to
Owner and Design Professional for their review and approval prior to submitting its first
Application for Payment. Contractor shall take into consideration such factors as
natural and practical lines of severability, sequencing effectiveness, access and
availability constraints, total time for completion, construction market conditions,
availability of labor and materials, community relations and any other factors pertinent to
saving time and costs,
33,2 A Subcontractor is any person or entity who is performing, furnishing, supplying
or providing any portion of the Work pursuant to a contract with Contractor. Contractor
shall be solely responsible for and have control over the Subcontractors. Contractor
shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests
for Proposal, with all affected Subcontractors and shall review the costs of those
GC,CA-H-25
proposals and advise Owner and Design Professional of their validity and
reasonableness, acting in Owner's best interest, prior to requesting approval of any
Change Order from Owner. All Subcontractors performing any portion of the Work on
this Project must be "qualified" as defined in Collier County Ordinance 87-25, meaning a
person or entity that has the capability in all respects to perform fully the Agreement
requirements with respect to its portion of the Work and has the integrity and reliability
to assure good faith performance.
33.3 In addition to those Subcontractors identified in Contractor's bid that were
approved by Owner, Contractor also shall identify any other Subcontractors, including
their addresses, licensing information and phone numbers, it intends to utilize for the
Project prior to entering into any subcontract or purchase order and prior to the
Subcontractor commencing any work on the Project. The list identifying each
Subcontractor cannot be modified, changed, or amended without prior written approval
from Owner. Any and all Subcontractor work to be self-performed by Contractor must
be approved in writing by Owner in its sole discretion prior to commencement of such
work, Contractor shall continuously update that Subcontractor list, so that it remains
current and accurate throughout the entire performance of the Work.
33,4 Contractor shall not enter into a subcontract or purchase order with any
Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not
be required to contract with anyone it reasonably objects to. Contractor shall keep on
file a copy of the license for every Subcontractor and sub-subcontractor performing any
portion of the Work, as well as maintain a log of all such licenses, All subcontracts and
purchase orders between Contractor and its Subcontractors shall be in writing and are
subject to Owner's approval. Further, unless expressly waived in writing by Owner, all
subcontracts and purchase orders shall (1) require each Subcontractor to be bound to
Contractor to the same extent Contractor is bound to Owner by the terms of the
Contract Documents, as those terms may apply to the portion of the Work to be
performed by the Subcontractor, (2) provide for the assignment of the subcontract or
purchase order from Contractor to Owner at the election of Owner upon termination of
Contractor, (3) provide that Owner will be an additional indemnified party of the
subcontract or purchase order, (4) provide that Owner, Collier County Government, will
be an additional insured on all liability insurance policies required to be provided by the
Subcontractor except workman's compensation and business automobile policies, (5)
assign all warranties directly to Owner, and (6) identify Owner as an intended third-party
beneficiary of the subcontract or purchase order. Contractor shall make available to
each proposed Subcontractor, prior to the execution of the subcontract, copies of the
Contract Documents to which the Subcontractor will be bound, Each Subcontractor
shall similarly make copies of such documents available to its sub-subcontractors,
33,5 Each Subcontractor performing work at the Project Site must agree to provide
field (on-site) supervision through a named superintendent for each trade (e,g., general
concrete forming and placement, masonry, mechanical, plumbing, electrical and
roofing) included in its subcontract or purchase order. In addition, the Subcontractor
shall assign and name a qualified employee for scheduling direction for its portion of the
Work, The supervisory employees of the Subcontractor (including field superintendent,
GC-CA-H-26
foreman and schedulers at all levels) must have been employed in a supervisory
(leadership) capacity of substantially equivalent level on a similar project for at least two
years within the last five years. The Subcontractor shall include a resume of experience
for each employee identified by it to supervise and schedule its work,
33,6 Unless otherwise expressly waived by Owner in writing, all subcontracts and
purchase orders shall provide:
33.6,1 That the Subcontractor's exclusive remedy for delays in the
performance of the subcontract or purchase order caused by events beyond its control,
including delays claimed to be caused by Owner or Design Professional or attributable
to Owner or Design Professional and including claims based on breach of contract or
negligence, shall be an extension of its contract time,
33.6,2 In the event of a change in the work, the Subcontractor's claim for
adjustments in the contract sum are limited exclusively to its actual costs for such
changes plus no more than 10% for overhead and profit
33,6,3 The subcontract or purchase order, as applicable, shall require the
Subcontractor to expressly agree that the foregoing constitute its sole and exclusive
remedies for delays and changes in the Work and thus eliminate any other remedies for
claim for increase in the contract price, damages, losses or additional compensation.
Further, Contractor shall require all Subcontractors to similarly incorporate the terms of
this Section 33,6 into their sub-subcontracts and purchase orders.
33,6.4 Each subcontract and purchase order shall require that any claims by
Subcontractor for delay or additional cost must be submitted to Contractor within the
time and in the manner in which Contractor must submit such claims to Owner, and that
failure to comply with such conditions for giving notice and submitting claims shall result
in the waiver of such claims,
34. CONSTRUCTION SERVICES
34,1 Contractor shall maintain at the Project site, originals or copies of,
on a current basis, all Project files and records, including, but not limited to, the following
administrative records:
34.1,1
34,1,2
34.1,3
34.1.4
34,1,5
34.1.6
34,1,7
34,1,8
34,1,9
34.1.10
Subcontracts and Purchase Orders
Subcontractor Licenses
Shop Drawing Submittal/Approval Logs
Equipment PurchaselDelivery Logs
Contract Drawings and Specifications with Addenda
Warranties and Guarantees
Cost Accounting Records
Labor Costs
Material Costs
Equipment Costs
GC,CA-H-27
34.1,11
34.1,12
34.1,13
34.1,14
34,1.15
34.1.16
34,1.17
34,1,18
34,1.19
34.1,20
34.1,21
34,1,22
34,1.23
34,1,24
34.1,25
34.1,26
34,1,27
34,1,28
34.1,29
34.1,30
34.1.31
34,1.32
Cost Proposal Request
Payment Request Records
Meeting Minutes
Cost-Estimates
Bulletin Quotations
Lab Test Reports
Insurance Certificates and Bonds
Contract Changes
Permits
Material Purchase Delivery Logs
Technical Standards
Design Handbooks
"As-Built" Marked Prints
Operating & Maintenance Instruction
Daily Progress Reports
Monthly Progress Reports
Correspondence Files
Transmittal Records
Inspection Reports
Punch Lists
PM IS Schedule and Updates
Suspense (Tickler) Files of Outstanding
Requirements
The Project files and records shall be available at all times to Owner and Design
Professional or their designees for reference, review or copying,
34,2 Contractor Presentations
At the discretion of the County, the Contractor may be required to provide a brief update
on the Project to the Collier County Board of County Commissioners, "Board", up to two
(2) times per contract term, Presentations shall be made in a properly advertised Public
Meeting on a schedule to be determined by the County Manager or his designee, Prior
to the scheduled presentation date, the Contractor shall meet with appropriate County
staff to discuss the presentation requirements and format. Presentations may include,
but not be limited to, the following information: Original contract amount, project
schedule, project completion date and any changes to the aforementioned since Notice
to Proceed was issued.
35. SECURITY
If required, Contractor shall be responsible for the costs of providing background checks
and drug testing for all employees that shall provide services to the County under this
Agreement. This may include, but not be limited to, checking federal, state and local
law enforcement records, including a state and FBI fingerprint check, credit reports,
education, residence and employment verifications and other related records,
Contractor shall be required to maintain records on each employee and make them
available to the County for at least four (4) years,
GC-CA-H-28
36. VENUE
Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or
state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction
on all such matters,
37. VALUE ENGINEERING
All projects with an estimated cost of $10 million or more shall be reviewed for
consideration of a Value Engineering (VE) study conducted during project development.
A "project" shall be defined as the collective contracts, which may include but not be
limited to: design, construction, and construction, engineering and inspection (CEI)
services. Additionally, any project with an estimated construction value of $2 million or
more may be reviewed for VE at the discretion of the County,
38. ABOVEGROUND/UNDERGROUND TANKS
An underground 62-761, Florida Administrative Code (FAC,) or aboveground 62-762,
FAC, regulated tank requires notification to the 'County' prior to installation or closure
of the tank. The Pollution Control Department (239-252-2502), via contract GC-690
with the Florida Department of Environmental Protection (FDEP), is the County (local
program) for the purposes of these rules.
Regulated tanks require notification to the 'county' local program thirty (30) days prior to
installation and again forty-eight (48) hours prior to commencement of the installation.
Closure activities require a ten (10) day notification and then a forty-eight (48) hour
notification prior to commencement. The notification is to allow for scheduling of the
inspections pertaining to the installation/closure activities, A series of inspections will
be scheduled based upon system design after discussing the project with the
contractor/project manager. Specifics on applicability, exemptions, and requirements
for regulated pollutant storage tank systems can be found in 62-761, FAC. and 62-762,
F,A.C, or you may contact the Pollution Control Department with your questions.
Please note that equipment must be listed on the FDEP approved equipment list and
will be verified at inspection along with installation and testing procedures, The
approved equipment list is constantly updated and can be found at the FDEP Storage
Tank Regulation website along with rules, forms and other applicable information.
39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR,
EMPLOYEES.
The Contractor shall employ people to work on Owner's projects who are neat, clean,
well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor
shall supply competent employees who are physically capable of performing their
employment duties, The Owner may require the Contractor to remove an employee it
deems careless, incompetent, insubordinate or otherwise objectionable and whose
continued employment on Owner's projects is not in the best interest of the County,
GC-CA-H-29
EXHIBIT I
SUPPLEMENTAL TERMS AND CONDITIONS
1, The County may, at its discretion, use VISNMASTER card credit network as a
payment vehicle for goods and/or services purchased as a part of this contract.
Provided Under Separate File
GC,CA-I-1
EXHIBIT J
TECHNICAL SPECIFICATIONS
Provided Under Separate File
GC-CA-J-1
EXHIBIT K
PERMITS
Provided Under Separate File
GC-CA-K-1
EXHIBIT L
STANDARD DETAILS
Provided Under Separate File
GC,CA-L-1
EXHIBIT M
PLANS AND SPECIFICATIONS
Provided Under Separate File
GC,CA-M-1
EXHIBIT M
PLANS AND SPECIFICATIONS
The following special provisions, taken from Division I of the FDOT Standard
Specifications for Road and Bridge Construction (2007, Division I, sections 1,4,5,7,
8, 9 and 2000, Division I, section 6) are adopted and made a part ofthis contract.
Many sections of Division I have been deleted and in some cases replaced by
provisions in EXHIBIT H. The Contractor is responsible for reviewing all contract
documents and sections. If a section within the FDOT Specifications for Road and
Bridge Construction is deleted and there is no section in EXHIBIT H that section is
deleted and not applicable to this project.
DIVISION II and III of the FDOT Standard Specifications for Road and Bridge
Construction (2007) and the following special provisions amending the standard
specifications are adopted and made a part of this contract as amended.
Any references in Division II and III to sections within Division I which have been
deleted and replaced by provisions in Exhibit H shall be treated as references to the
applicable section within Exhibit H.
ORDER OF PRECEDENCE
The order of precedence provided in Section 17 of the Construction Agreement is
supplemented by the following:
1. Exhibit I - Supplemental Conditions.
2. Construction Agreement
3. Exhibit H - General Terms and Conditions
4, Advertisement for bids, instructions to bidders, proposal, contract form,
payment and performance bond,
5. Exhibit M - Plans
6, Exhibit M - Specifications
7. Exhibit J - Technical Specifications
8. FDOT Roadway and Traffic Design Standards
9, FDOT Standard Specifications for Roadway and Bridge Construction
I
-
I. GENERAL REQUIREMENTS & COVENANTS
Section I Definitions and Terms ........................................................3
Section 2 NOTE: Omitted Entirely (Proposed Requirements & Conditions)... .11
Section 3 NOTE: Omitted Entirely (Award and Execution of Contract)..... .....11
Section 4 Scope of Work. ... .............. ............. ...... ................ ..... ......11
Section 5 Control of Work....... . .......... ...... ............ ......... ....... ...........17
Section 6 Control of Materials.. .......... ..................... .......... ..... ...........28
Section 7 Legal Requirements and Responsibility to the Public.................. .32
Section 8 Prosecution and Progress. .. .. . .. .. .. . .. . .. .. . .. . .. . .. .. .. .. .. . . .. .. . . .. .. .. Al
Section 9 Measurement and Payment............... ........ ...................... .....52
II. CONSTRUCTION DETAILS
Superpave Asphalt Concrete ...... ...... ... ......... ......... ...... ... ...... ........ ....57
SECTION 1 DEFINITIONS AND TERMS
2
1-1 General.
These Specifications are written to the bidder, prior to award of the Contract, and to the
Contractor. Within Divisions I and II of the specifications, sentences that direct the
Contractor to perform work are written in the active voice-imperative mood. These
directions to the Contractor are written as commands. In the imperative mood, the subject
"the bidder" or "the Contractor" is understood.
All other requirements to be performed by others, with the exception of the Method of
Measurement and the Basis of Payment Articles, have been written in the active voice,
but not in the imperative mood. Sentences written in the active voice identifY the party
responsible for performing the action. For example, "The Engineer will determine the
density of the compacted material." Certain requirements of the Contractor may also be
written in the active voice, rather than active voice-imperative mood.
Division III of the Specifications (Materials) is written in the passive voice writing style.
1-2 Abbreviations.
The following abbreviations, when used in the Contract.Documents, represent the full
text shown.
AAN American Association of Nurserymen, Inc)
AASHTO American Association of State Highway and Transportation Officials
ACI American Concrete Institute
AGC The Associated General Contractors of America, Inc.
AGMA American Gear Manufacturers Association
AlA American Institute of Architects.
AISI American Iron and Steel Institute
ANSI American National Standards Institute, Inc.
AREA American Railway Engineering Association
ASCE American Society of Civil Engineers
ASME American Society of Mechanical Engineers
ASTM American Society for Testing and Materials
A WG American Wire Gauge
A WP A American Wood Preservers Association
A WS American Welding Society
A WW A American Water Warks Association
CRSI Concrete Reinforcing Steel Institute
EASA Electrical Apparatus Service Association
EP A Environmental Protection Agency of the United States Government
FDOT Florida Department of Transportation
FHWA Federal Highway Administration
FSS Federal Specifications and Standards
IEEE Institute of Electrical and Electronics Engineers
IES Illuminating Engineering Society
IPCEA Insulated Power Cable Engineers Association
ISO International Organization for Standards
MSTCSD Minimum Specifications for Traffic Control Signals and Devices
MUTCD Manual on Uniform Traffic Control Devices
3
- ...."._-'"
NEC National Electrical Code
NEMA National Electrical Manufacturers Association
NFP A National Fire Protection Association
NIST National Institute far Standards and Technology
NOAA National Oceanic and Atmospheric Administration
OSHA Occupational Safety and Health Administration
SAE Society of Automotive Engineers
SI International System of Units
SSPC Society of Protective Coatings
UL Underwriters' Laboratories
Each of the above abbreviations, when followed by a number or letter designation, or
combination of numbers and letters, designates a specification, test method, or other code
or recommendation of the particular authority or organization shown.
Use standards, specifications, test methods, or other codes as specified in the current
edition at the time of the bid opening.
1-3 Definitions.
The following terms, when used in the Contract Documents, have the meaning described
Advertisement.
The public announcement, as required by law, inviting bids for work to be performed or
materials to be furnished, usually issued as "Notice to Contractars," or "Notice to
Bidders."
Article.
The numbered prime subdivision of a Section of these Specifications.
Bidder.
An individual, firm, or corporation submitting a proposal for the proposed work.
Bridge.
A structure, including supports, erected over a depression or over an obstruction such as
water, highway or railway, or for elevated roadway, for carrying traffic or other moving
loads, and having a length, measured along the center of the roadway, of more than 20
feet between the inside faces of end supports. A multiple-span box culvert is considered a
bridge, where the length between the extreme ends of the openings exceeds 20 feet.
Calendar day.
Every day shown on the calendar, ending and beginning at midnight.
Change Order.
A written order issued by the Department and accepted by the Contractor, covering minor
changes in the plans, specifications, or quantities of work, within the scope ofthe
Contract, when prices for the items of work affected are previously established in the
Contract.
4
Contract.
The term "Contract" means the entire and integrated agreement between the parties
thereunder and supersedes all prior negotiations, representations, or agreements, either
written or oral. The Contract Documents form the Contract between the Department and
the Contractor setting forth the obligations of the parties thereunder, including, but not
limited to, the performance of the Work and the basis of payment.
Contract Claim (Claim).
A written demand submitted to the Department by the Contractor in compliance with 5-
12.3 seeking additional monetary compensation, time, or other adjustments to the
Contract, the entitlement or impact of which is disputed by the Department.
Contract Documents.
The term "Contract Documents" includes: Advertisement for Proposal, Proposal,
Certification as to Publication and Notice of Advertisement for Proposal, Appointment of
Agent by Nonresident Contractors, Noncollusion Affidavit, Warranty Concerning
Solicitation of the Contract by Others, Resolution of Award of Contract, Executed Form
of Contract, Performance Bond and Payment Bond, Standard Specifications,
Supplemental Specifications, Special Provisions, plans, Addenda, or other information
mailed ar otherwise transmitted to the prospective bidders prior to the receipt of bids,
change orders, field orders, and supplemental agreements, all of which are to be treated
as one instrument whether or not set forth at length in the form of contract.
Note: As used in Sections 2 and 3 only, Contract Documents do not include change
arders, field orders, and supplementary agreements. As used in Section 2 only, Contract
Documents also do not include Resolution of Award of Contract, Executed Form of
Contract, and Performance and Payment Bond.
Contract Bond.
The security furnished by the Contractor and the surety as a guaranty that the Contractor
shall fulfill the terms of the Contract and pay all legal debts pertaining to the construction
of the project.
Contract Letting.
The date that the Department opened the bid proposals.
Contract Time.
The number of calendar days allowed for completion of the Contract work, including
authorized time extensions.
Contractor.
The individual, firm, joint venture, or company contracting with the Department to
perform the work.
Contractor's Engineer of Record.
A Professional Engineer registered in the State of Florida, other than the Engineer of
Record or his subcontracted consultant, who undertakes the design and drawing of
components of the permanent structure as part of a redesign or VECP, or for repair
5
_....'-
designs and details of the permanent work. The Contractor's Engineer of Record may
also serve as the Specialty Engineer.
The Contractor's Engineer of Recard must be an employee of a pre-qualified firm. The
firm shall be pre-qualified in accordance with the Rules of the Department of
Transportation, Chapter 14-75. Any Corporation or Partnership offering engineering
services must hold a Certificate of Authorization from the Florida Department of
Business and Professional Regulation.
As an alternate to being an employee of a pre-qualified firm, the Contractor's Engineer of
Record may be a pre-qualified Specialty Engineer. For items of the permanent work
declared by the State Construction Office to be "majar" or "structural", the work
performed by a pre-qualified Specialty Engineer must be checked by another pre-
qualified Specialty Engineer. An individual Engineer may become pre-qualified in the
work groups listed in the Rules of the Department of Transportation, Chapter 14-75, if
the requirements for the Professional Engineer are met for the individual work groups.
Pre-qualified Specialty Engineers are listed on the State Construction Website. Pre-
qualified Specialty Engineers will not be authorized to perform redesigns or VECP
designs of items fully detailed in the plans.
Controlling Work Items.
The activity or work item on the critical path having the least amount of total float. The
controlling item of work will also be referred to as a Critical Activity.
Culverts.
Any structure not classified as a bridge that provides an opening under the roadway.
Delay.
Any unanticipated event, action, force or factor which extends the Contractor's time of
performance of any controlling work item under the Contract. The term "delay" is
intended to cover all such events, actions, forces or factors, whether styled "delay",
"disruption", "interference", "impedance", "hindrance", or otherwise, which are beyond
the control of and not caused by the Contractor, or the Contractor's subcontractors,
materialmen, suppliers or other agents. This term does not include "extra work".
Department.
Collier County Board of County Commissioners
Developmental Specification.
See definition for Specifications.
Engineer.
The Director, Collier County Transportation and Construction Management Department
(TECM), acting directly or through duly autharized representatives; such representatives
acting within the scope of the duties and authority assigned to them.
Note: In order to avoid cumbersome and confusing repetition of expressions in these
Specifications, it is provided that whenever anything is, or is to be done, if, as, or, when,
6
or where "acceptable, accepted, approval, approved, authorized, condemned, considered
necessary, contemplated, deemed necessary, designated, determined, directed,
disapproved, established, given, indicated, insufficient, ordered, permitted, rejected,
required, reserved, satisfactory, specified, sufficient, suitable, suspended, unacceptable,
or unsatisfactory," it shall be understood as if the expression were followed by the words
"by the Engineer," "to the Engineer," or "of the Engineer."
Engineer of Record.
The Professional Engineer or Engineering Firm registered in the State of Florida that
develops the criteria and concept for the project, performs the analysis, and is responsible
for the preparation of the Plans and Specifications. The Engineer of Record may be
Departmental in-house staff or a consultant retained by the Department.
The Contractor shall not employ the Engineer of Record as the Contractor's Engineer of
Record or as a Specialty Engineer.
Equipment.
The machinery and equipment, together with the necessary supplies for upkeep and
maintenance thereof, and all other tools and apparatus necessary for the construction and
acceptable completion of the work.
Extra Work.
Any "work" which is required by the Engineer to be performed and which is not
otherwise covered or included in the project by the existing Contract Documents, whether
it be in the nature of additional work, altered work, deleted work, work due to differing
site conditions, or otherwise. This term does not include a "delay".
Highway, Street, or Road.
A general term denoting a public way for purposes of vehicular travel, including the
entire area within the right-of-way.
Holidays.
Days designated by Collier County as holidays, which include, but are not limited to,
New Year's Day, Martin Luther King's Birthday, Memorial Day, Independence Day,
Labor Day, Veterans' Day, Thanksgiving Day and the following Friday, and Christmas
Day.
Inspector.
An autharized representative of the Engineer, assigned to make official inspections of the
materials furnished and of the work performed by the Contractor.
Laboratory.
The official testing laboratory used by the Department.
Major Item of Work.
Any item of work having an original Contract value in excess of5% of the original
Contract amount.
7
..~..-.
Materials.
Any substances to be incorporated in the work under the Contract.
Median.
The portion of a divided highway or street separating the traveled ways for traffic moving
in opposite directions.
Plans.
The approved plans, including reproductions thereof, showing the location, character,
dimensions, and details of the work.
Proposal (Bid, Bid Proposal).
The offer of a bidder, on the prescribed form, to perform the work and to furnish the
labor and materials at the prices quoted.
ProposaI/Bid Forms
The official form or the expedite program generated bid item sheets on which the
Department requires formal bids to be prepared and submitted for the work.
Proposal Guaranty
The security furnished by the bidder as guaranty that the bidder will enter into the
Contract for the wark if the Department accepts the proposal.
Right-of-Way.
The land that the Department has title to, or right of use, for the road and its structures
and appurtenances, and for material pits furnished by the Department.
Roadbed.
The portion of the roadway occupied by the subgrade and shoulders.
Roadway.
The portion of a highway within the limits of construction.
Secretary.
Transportation Administrator, Collier County, acting directly or through an assistant or
other representative authorized by him"
Section.
A numbered prime division of these Specifications.
Special Provisions.
See definition for Specifications.
Specialty Engineer.
A Professional Engineer registered in the State of Florida, other than the Engineer of
Record or his subcontracted consultant, who undertakes the design and drawing
preparation of components, systems, or installation methods and equipment for specific
temporary portions of the project work or for special items of the permanent works not
8
fully detailed in the plans and required to be furnished by the Contractor such as but not
limited to pot bearing designs, non-standard expansion joints, MSE wall designs and
other specialty items. The Specialty Engineer may also provide designs and details for
items of the permanent work declared by the State Construction Office to be "minor" or
"non-structural". The Specialty Engineer may be an employee or officer of the Contractor
or a fabricatar, an employee or officer of an entity providing components to a fabricator,
or an independent consultant.
For items of work not specifically covered by the Rules of the Department of
Transportation, a Specialty Engineer is qualified if he has the following qualifications:
(1) Registration as a Professional Engineer in the State of Florida.
(2) The education and experience necessary to perform the submitted design as required
by the Florida Department of Business and Professional Regulation.
Specifications.
The directions, provisions, and requirements contained herein, together with all
stipulations contained in the Contract Documents, setting out or relating to the method
and manner of performing the work, or to the quantities and qualities of materials and
labor to be furnished under the Contract.
A. Standard Specifications: "Standard Specifications for Road and Bridge Construction"
a bound book, applicable to all Department Contracts containing adopted requirements,
setting out or relating to the method or manner of performing work, or to the quantities
and qualities of materials and labor.
B. Supplemental Specifications: Approved additions and revisions to the Standard
Specifications, applicable to all Department Contracts.
C. Special Provisions: Specific clauses adopted by the Department that add to or revise
the Standard Specifications or supplemental specifications, setting forth conditions
varying from or additional to the Standard Specifications applicable to a specific project.
D. Technical Special Provisions: Specifications, of a technical nature, prepared, signed,
and sealed by an Engineer registered in the State of Florida other than the State
Specifications Engineer or his designee, that are made part of the Contract as an
attachment to the Contract Documents.
E. Developmental Specification: A specification developed around a new process,
procedure, or material.
Standard Specifications.
See definition for Specifications.
State.
State of Florida.
Subarticle.
A headed and numbered subdivision of an Article of a Section of these Specifications.
Subgrade.
The portion of the roadbed immediately below the base course or pavement, including
below the curb and gutter, valley gutter, shoulder and driveway pavement. The subgrade
9
limits ordinarily include those portions of the roadbed shown in the plans to be
constructed to a design bearing value or to be otherwise specially treated. Where no
limits are shown in the plans, the subgrade section extends to a depth of 12 inches below
the bottom of the base or pavement and outward to 6 inches beyond the base, pavement,
or curb and gutter.
Substructure.
All of that part of a bridge structure below the bridge seats, including the parapets,
backwalls, and wingwalls of abutments.
Superintendent.
The Contractor's authorized representative in responsible charge of the work.
Superstructure.
The entire bridge structure above the substructure, including anchorage and anchor bolts,
but excluding the parapets, backwalls, and wingwalls of abutments.
Supplemental Agreement
A written agreement between the Contractor and the Department, and signed by the
surety, modifying the Contract within the limitations set forth in these Specifications.
Surety.
The corporate body that is bound by the Contract Bond with and for the Contractor and
responsible for the performance of the Contract and for payment of all legal debts
pertaining thereto.
Technical Special Provisions.
See definition for Specifications.
Traveled Way.
The portion of the roadway providing for the movement of vehicles, exclusive of
shoulders and auxiliary lanes.
Unilateral Payment.
A payment of money made to the Contractor by the Department pursuant to Section
337.11(11), Florida Statutes (1997), for sums the Department determines to be due to the
Contractor for work performed on the project, and whereby the Contractor by acceptance of
such payment does not waive any rights the Contractor may otherwise have against the
Department for payment of any additional sums the Contractor claims are due for the work.
Work.
All labor, materials and incidentals required to execute and complete the requirements of
the Contract including superintendence, use of equipment and tools, and all services and
responsibilities prescribed or implied.
Working Day.
Any calendar day on which the Contractor works or is expected to work in accordance
with the approved work progress schedule.
10
SECTION 2 NOTE:
OMITTED ENTIRELY
(proposal Requirements and Conditions 2007)
SECTION 3 NOTE:
OMITTED ENTIRELY
(Award and Execution of Contract 2007)
SECTION 4
SCOPE OF THE WORK
4-1 Omitted Entirely (Intent of Contract)
4-2 Omitted Entirely (Work not Covered by Standard Specifications)
4-3 Alteration of Plans or of Character of Work.
4-3.1 General: The Engineer reserves the right to make, at any time prior to or during
the progress of the work, such increases or decreases in quantities, whether a significant
change or not, and such alterations in the details of construction, whether a substantial
change or not, including but not limited to alterations in the grade or alignment of the
road or structure or both, as may be found necessary or desirable by the Engineer. Such
increases, decreases or alterations shall not constitute a breach of Contract, shall not
invalidate the Contract, nor release the Surety from any liability arising out ofthis
Contract ar the Surety bond. The Contractor agrees to perform the work, as altered, the
same as if it had been a part of the original Contract.
The term "significant change" applies only when:
(A) The Engineer determines that the character of the work as altered
differs materially in kind or nature from that involved or included in the original
proposed construction, or
(B) A major item of work, as defined in 1-3, is increased in excess of
125% or decreased below 75% of the original Contract quantity. The Department will
apply any price adjustment for an increase in quantity only to that portion in excess of
125% of the original Contract item quantity, or in case of a decrease below 75% to the
actual amount of work performed, such allowance to be determined in accordance with
4-3.2, below.
In the instance of (A) above, the determination by the Engineer shall be conclusive
and shall not subject to challenge by the Contractor in any forum, except upon the
Contractor establishing by clear and convincing proof that the determination by the
Engineer was without any reasonable and good-faith basis.
II
--- -.... ..._~,
4-3.2.1 Allowable Costs for Extra Work: The Engineer may direct in writing that
extra work be done and, at the Engineer's sole discretion, the Contractor will be paid
pursuant to an agreed Supplemental Agreement or in the following manner:
(a) Labor and Burden: The Contractor will receive payment for actual costs of
direct labor and burden for the additional or unforeseen work. Labar includes foremen
actually engaged in the work; and will not include project supervisory personnel nor
necessary on-site clerical staff, except when the additional or unforeseen work is a
controlling work item and the performance of such controlling work item actually
extends completion of the project due to no fault of the Contractor. Compensation for
project supervisory personnel, but in no case higher than a Project Manager's position,
shall only be for the pro-rata time such supervisory personnel spent on the contract. In no
case shall an officer or director of the Company, nor those persons who own more than
1% ofthe Company, be considered as project supervisory personnel, direct labor or
foremen hereunder.
Payment for burden shall be limited solely to the following:
Table 4-3.2.1
Item Rate
FICA Rate established b Law
FUTAlSUTA Rate established by Law
Medical Insurance Actual
Holiday, Sick & Actual
Vacation benefits
Retirement benefits Actual
Workers Compensation Rates based on the National Council on Compensation
Insurance basic rate tables, adjusted by Contractor's actual
experience modification factor in effect at the time of the
additional work or unforeseen work.
Per Diem Actual but not to exceed State of Florida's rate
Insurance* Actual
*Compensation for Insurance is limited solely to General Liability Coverage and does not
include any other insurance coverage (such as, but not limited to, Umbrella Coverage,
Automobile Insurance, etc.). .__~..____._~___u_.__,.,._.__~.
At the Pre-construction conference, certifY to the Engineer the following:
(1) A listing of on-site clerical staff, supervisory personnel and their pro-rated
time assigned to the contract,
(2) Actual Rate for items listed in Table 4-3.2.1,
(3) Existence of employee benefit plan for Holiday, Sick and Vacation benefits
and a Retirement Plan, and,
(4) Payment of Per Diem is a company practice for instances when compensation
for Per Diem is requested.
Such certification must be made by an officer or director of the Contractor with
authority to bind the Contractor. Timely certification is a condition precedent to any right
of the Contractor to recover compensations for such costs, and failure to timely submit
the certification will constitute a full, complete, absolute and irrevocable waiver by the
12
Contractor of any right to recover such costs. Any subsequent changes shall be certified
to the Engineer as part of the cost proposal or seven calendar days in advance of
performing such extra work.
(b) Materials and Supplies: For materials accepted by the Engineer and used on
the project, the Contractor will receive the actual cost of such materials incorporated into
the work, including Contractor paid transportation charges (exclusive of equipment as
hereinafter set forth). For supplies reasonably needed for performing the work, the
Contractor will receive the actual cost of such supplies.
(c) Equipment: For any machinery or special equipment (other than small
tools), including fuel and lubricant, the Contractor will receive 100% of the "Rental Rate
Blue Book" for the actual time that such equipment is in operation on the work, and 50%
of the "Rental Rate Blue Book" for the time the equipment is directed to standby and
remain on the project site, to be calculated as indicated below. The equipment rates will
be based on the latest edition (as of the date the work to be performed begins) of the
"Rental Rate Blue Book for Construction Equipment" or the "Rental Rate Blue Book for
Older Construction Equipment," whichever is applicable, as published by Machinery
Information Division ofPRIMEDIA Information, Inc. (version current at the time of bid),
using all instructions and adjustments contained therein and as modified below. On all
projects, the Engineer will adjust the rates using regional adjustments and Rate
Adjustment Tables according to the instructions in the Blue Book.
Allowable Equipment Rates will be established as set out below:
(1) Allowable Hourly Equipment Rate = Monthly Ratel176
x Adjustment Factors x 100%.
(2) Allowable Hourly Operating Cost = Hourly Operating
Cost x 100%.
(3) Allowable Rate Per Hour = Allowable Hourly
Equipment Rate + Allowable Hourly Operating Cost.
(4) Standby Rate = Allowable Hourly Equipment Rate x 50%.
The Monthly Rate is The Basic Machine Rate Plus Any Attachments. Standby
rates will apply when equipment is not in operation and is directed by the Engineer to
standby at the project site when needed again to complete work and the cost of moving
the equipment will exceed the accumulated standby cost. Standby rates will not apply on
any day the equipment operates for eight or more hours. Standby payment will be limited
to only that number of hours which, when added to the operating time for that day equals
eight hours. Standby payment will not be made on days that are not normally considered
work days on the project.
The Department will allow for the cost of transporting the equipment to and from
the location at which it will be used. If the equipment requires assembly or disassembly
for transport, the Department will pay for the time to perform this work at the rate for
standby equipment.
Equipment may include vehicles utilized only by Labor, as defined above.
(d) Indirect Costs, Expenses, and Profit: Compensation for all indirect
13
costs, expenses, and profit of the Contractor, including but not limited to overhead of any
kind, whether jobsite, field office, division office, regional office, home office, ar
otherwise, is expressly limited to the greater of either (1) or (2) below:
(1) Solely a mark-up of 17.5% on the payments in (a) through (c), above.
(i) Bond: The Contractor will receive compensation for any
premium for acquiring a bond for such additional or unforeseen work; provided,
however, that such payment for additional bond will only be paid upon presentment to
the Department of clear and convincing proof that the Contractor has actually provided
and paid for separate bond premiums for such additional or unforeseen work in such
amount.
(ii) The Contractor will be allowed a markup of 10% on the first
$50,000 and a markup of 5% on any amount over $50,000 on any subcontract directly
related to the additional or unforeseen work. Any such subcontractor mark-up will be
allowed only by the prime Contractor and a first tier subcontractor, and the Contractor
must elect the markup for any eligible first tier subcontractor to do so.
(2) Solely the formula set forth below and only as applied solely as
to such number of calendar days of entitlement that are in excess often cumulative
calendar days as defined below.
D =A x C
B
Where A = Original Contract Amount
B = Original Contract Time
C=8%
D = Average Overhead Per Day
Cumulative Calendar Days is defined as the cumulative total number of calendar
days granted for time extension due to delay of a controlling work item caused solely by
the Department is, or the cumulative total number of calendar days for which entitlement
to a time extension due to delay of a controlling work item caused solely by the
Department is otherwise ultimately determined in favor of the Contractor to be.
Further, in the event there are concurrent delays to one or more controlling work
items, one or more being caused by the Department and one ar more being caused by the
Contractor, the Contractor shall be entitled to a time extension for each day that a
controlling work item is delayed by the Department but shall have no right to nor receive
any monetary compensation for any indirect costs for any days of concurrent delay. No
compensation, whatsoever, will be paid to the Contractor for any jobsite overhead and
other indirect impacts when the total number of calendar days granted for time extension
due to delay of a controlling work item caused solely by the Department is, or the total
number of calendar days for which entitlement to a time extension due to delay of a
controlling work item caused solely by the Department is otherwise ultimately
determined in favor of the Contractor to be, equal to or less than ten calendar days and
the Contractor also fully assumes all monetary risk of any and all partial or single
calendar day delay periods, due to delay of a controlling work item caused solely by the
Department, that when cumulatively totaled together are equal to or less than ten calendar
14
days and regardless of whether monetary compensation is otherwise provided for
hereunder for one or more calendar days of time extension entitlement for each calendar
day exceeding ten calendar days. All calculations under this provision shall exclude
weather days, and days granted for performing additional work.
4-3.2.2 Subcontracted Work: For work performed by a subcontractor,
compensation for the additional or unforeseen work shall be solely limited to as provided
for in 4-3.2.1 (a), (b), (c) and (d)(I), with the exception of, in the instance of
subcontractor performed work only, the subcontractor may receive compensation for any
premium for acquiring a bond for the additional or unforeseen work; provided, however,
that such payment for additional subcontractor bond will only be paid upon presentment
to the Department of clear and convincing proof that the subcontractor has actually
provided and paid for separate bond premiums for such additional or unforeseen work in
such amount.
The Contractor shall require the subcontractor to provide a certification, in
accordance with 4-3.2.I(a), as part of the cost proposal and provide such to the Engineer.
Such certification must be made by an officer or director of the subcontractor with
authority to bind the subcontractor. Timely certification is a condition precedent to any
right of the Contractor to recover compensation for such subcontractor costs, and failure
to timely submit the certification will constitute a full, complete, absolute and irrevocable
waiver by the Contractor of any right to recover such subcontractor costs.
4-3.3 No Waiver of Contract: Changes made by the Engineer will not be
considered to waive any of the provisions of the Contract, nor may the Contractor make
any claim for loss of anticipated profits because of the changes, or by reason of any
variation between the approximate quantities and the quantities of work actually
performed. All work shall be performed as directed by the Engineer and in accordance
with the Contract Documents.
4-3.4 Conditions Requiring a Supplemental Agreement or Unilateral
Payment: A Supplemental Agreement or Unilateral Payment will be used to clarifY the
plans and specifications of the Contract; to document quantity overruns that exceed 5%
of the original Contract amount; to provide for unforeseen work, grade changes, or
alterations in plans which could not reasonably have been contemplated or foreseen in the
original plans and specifications; to change the limits of construction to meet field
conditions; to provide a safe and functional connection to an existing pavement; to settle
documented Contract claims; to make the project functionally operational in accordance
with the intent of the original Contract and subsequent amendments thereto.
A Supplemental Agreement or Unilateral Payment may be used to expand the
physical limits of the project only to the extent necessary to make the project functionally
operational in accordance with the intent of the original Contract. The cost of any such
agreement extending the physical limits of the project shall not exceed $100,000 or 10%
of the original Contract price, whichever is greater.
Perform no work to be covered by a Supplemental Agreement or Unilateral
Payment before written authorization is received from the Engineer. The Engineer's
written authorization will set forth sufficient work information to allow the work to
begin. The wark activities, terms and conditions will be reduced to written Supplemental
Agreement ar Unilateral Payment form promptly thereafter. No payment will be made on
15
.....~..
a Supplemental Agreement or Unilateral Payment prior to the Department's approval of
the document.
4-3.5 Extra Work: Extra work authorized in writing by the Engineer will be paid
in accordance with the formula in 4-3.2. Such payment will be the full extent of all
monetary compensation entitlement due to the Contractor for such extra work. Any
entitlement to a time extension due to extra work will be limited solely to that provided
for in 4-3.2 for additional work.
4-3.6 Connections to Existing Pavement, Drives and Walks: Generally adhere
to the limits of construction at the beginning and end of the project as detailed in the
plans. However, if the Engineer determines that it is necessary to extend the construction
in order to make suitable connections to existing pavement, the Engineer will authorize
such a change in writing. For necessary connections to existing walks and drives that are
not indicated on the plans, the Engineer will provide direction regarding the proper
connections in accordance with the Design Standards.
4-3.7 Differing Site Conditions: During the progress of the work, if subsurface
or laten physical conditions are encountered at the site differing materially from those
indicated in the Contract, ar if unknown physical conditions of an unusual nature
differing materially from those ordinarily encountered and generally recognized as
inherent in the work provided for in the Contract are encountered at the site, the party
discovering such conditions shall promptly notify the other party in writing of the
specific differing conditions before the Contractor disturbs the
conditions or performs the affected work.
Upon receipt of written notification of differing site conditions from the
Contractor, the Engineer will investigate the conditions, and if it is determined that the
conditions materially differ and cause an increase or decrease in the cost or time required
for the performance of any work under the Contract, an adjustment will be made,
excluding loss of anticipated profits, and the Contract will be modified in writing
accordingly. The Engineer will notifY the Contractor whether or not an adjustment of the
Contract is warranted.
The Engineer will not allow a Contract adjustment for a differing site condition
unless the Contractor has provided the required written notice.
The Engineer will not allow a Contract adjustment under this clause for any
effects caused to any other Department or non-Department projects on which the
Contractor may be working.
4-3.8 Changes Affecting Utilities: The Contractor shall be responsible for
identifYing and assessing any potential impacts to a utility that may be caused by thc
changes proposed by the Contractor, and the Contractor shall at the time of making the
request for a change notifY the Department in writing of any such potential impacts to
utilities.
Department approval of a Contractor proposed change does not relieve the Contractor of
sole responsibility for all utility impacts, costs, delays or damages, whether direct or
indirect, resulting from Contractor initiated changes in the design or construction
activities from those in the original Contract Specifications, design plans (including
traffic control plans) or other Contract Documents and which effect a change in utility
work different from that shown in the utility plans, joint project agreements or utility
relocation schedules.
16
4-4 Omitted Entirely (Unforeseeable Work)
4-5 Rights in and Use of Materials Found on the Site of the Work.
4-5.1 Ownership and Disposal of Existing Materials: Take ownership and
dispose of all materials that are not designated as the property of other parties, in both
roadway and structures, found on the right-of-way, and all material in structures
designated for removal. Such materials do not include earth or other excavated material
required for the construction of the project. During construction, the Contractor may use
materials from existing structures that are required to be removed and that are designated
to remain the property of the Department. Do not cut or otherwise damage such material
during removal unless the Engineer gives permission to do so. Store material in an
accessible location as the Engineer directs. The Department is not responsible for the
quality or quantity of any material salvaged.
4-5.2 Ornamental Trees and Shrubs: Take ownership of all ornamental trees or
shrubs existing in the right-of-way that are required to be removed for the construction
operations and which are not specifically designated on the plans to be reset, or to be
removed by others prior tothe construction operations.
4-6 Omitted Entirely (Final Cleaning Up of Right-of-Way)
SECTION 5
CONTROL OF THE WORK
5-1 Plans and Working Drawings.
5-1.1 Contract Documents: The Contractor may purchase copies of the Standard
Specifications and Design Standards from the Department or access them from the
FDOT's website. Have available on the worksite, at all times, one copy of the Contract
Documents.
5-1.2 Department's Plans: Plans consist of general drawings showing such
details as are necessary to give a comprehensive idea of the construction contemplated. In
general, roadway plans will show alignment, profile grades, typical cross-sections and
general cross-sections. In general, structure plans will show in detail all dimensions of the
work contemplated. When the structure plans do not show the dimensions in detail, they
will show general features and such details as are necessary to give a comprehensive idea
of the structure.
Grades shown are finished grades, and B.M. Datum is North American Vertical
Datum 1988 (NA VD-1988) National Geodetic Vertical Datum of 1929 (NGVD-I929) or
other datum as noted in the plans.
5-1.3 Alterations in Plans: The Department will issue, in writing, all authorized
alterations affecting the requirements and information given on the approved plans.
5-1.4 Shop Drawings:
5-1.4.1. Definitions:
(a) Shop Drawings: All working, shop and erection drawings, associated
trade literature, calculations, schedules, manuals and similar documents submitted by the
Contractor to define some portion of the project work. The type of work includes both
permanent and temporary works as appropriate to the project.
17
.' --..,_._.~-,......
(b) Permanent Works: All the permanent structures and parts thereof
required of the completed Contract.
(c) Temporary Works: Any temporary construction work necessary for the
construction of the permanent works. This includes falsework, formwork, scaffolding,
shoring, temporary earthworks, sheeting, cofferdams, special erection equipment and the
like.
(d) Construction Affecting Public Safety: Construction that may
jeopardize public safety such as structures spanning functioning vehicular roadways,
pedestrian walkways, railroads, navigation channels of navigable waterways and walls or
other structure foundations located in embankments immediately adjacent to functioning
roadways. It does not apply to those areas of the site under the Contractor's control and
outside the limits of normal public access.
(e) Major and Unusual Structures: Bridges of complex geometry and/or
complex design. Generally, this includes the following types of structures:
I. Bridges with an individual span longer than 300 feet.
2. Structurally continuous superstructures with spans over 150 feet.
3. Steel box and plate girder bridges.
4. Steel truss bridges.
5. Concrete segmental and longitudinally post-tensioned continuous girder
bridges.
6. Cable stayed or suspension bridges.
7. Arch bridges.
8. Tunnels.
9. Movable bridges (specifically electrical and mechanical components).
10. Rehabilitation, widening, or lengthening of any of the above.
(f) Special Erection Equipment includes launching gantries, beam and
winch equipment, form travelers, stability towers, strong-backs, erection trusses,
launching noses or similar items made purposely for construction of the structure. It does
not apply to commonly available proprietary construction equipment such as cranes.
(g) Falsework includes any temporary construction work used to support
the permanent structure until it becomes self-supporting. Falsework includes steel or
timber beams, girders, columns, piles and foundations, and any proprietary equipment
including modular shoring frames, post shores, and adjustable horizontal shoring.
(h) Formwork includes any structure Of mold used to retain plastic or fluid
concrete in its designated shape until it hardens. FOfmwork compriscs common materials
such as wood or metal sheets, battens, soldiers and walers, ties, proprietary forming
systems such as stay-in-place metal fOffi1s, and proprietary supporting bolts, hangers and
brackets. Formwork may be either permanent formwork requiring a shop drawing
submittal such as stay-in-place metal or concrete forms, ar may be temporary formwork
which requires certification by the Specialty Engineer for Construction Affecting Public
Safety and for Major and Unusual Structures.
(i) Scaffolding is an elevated work platform used to support workmen,
materials and equipment, but not intended to support the structure.
(j) Shoring is a component of falsework such as horizontal, vertical or
inclined support members. In this Section, this term is interchangeable with falsework.
18
(k) Contractor Originated Designs: Items which the Contract Documents
require the Contractor to design, detail and incorporate into the permanent works.
5-1.4.2 Work Items Requiring Shop Drawings: In general, the
Department requires shop drawings for items of work not fully detailed in the plans
which require additional drawings and coordination prior to constructing the item,
including but not limited to:
(a) Bridge components not fully detailed in the plans, i.e. segments, steel
girder details, post-tensioning details, handrails, etc.
(b) Retaining Wall Systems
(c) Precast Box Culverts
(d) Non-standard lighting, signalization and signing structures and
components
(e) Building structures
(f) Drainage structures, attenuators, and other nonstructural items
(g) Design and structural details furnished by the Contractor in compliance
with the Contract
(h) Temporary Works affecting public safety
Additional clarification for certain types of bridge structures is
provided in 5-104.7. Other provisions of the Contract Documents may waive the
requirement for submittals for certain items; i.e., items constructed from standard
drawings or those complying with alternate details for prestressed members under
Section 450. Review the Contract Documents to determine the submittals required.
5-1.4.3 Schedule of Submittals: Prepare and submit a schedule of
submittals that identifies the work for which shop drawings apply. For each planned
submittal, define the type, and approximate number of drawings or other documents that
are included and the planned submittal date, considering the processing requirements
herein. Submit the schedule of submittals to the Department's Shop Drawing Review
Office and the Engineer of Record within 60 days ofthe start of the Contract, and prior to
the submission of any shop drawings.
Coordinate subsequent submittals with construction schedules to
allow sufficient time for review, approval, and re-submittal as necessary.
5-1.4.4 Style, Numbering, and Material of Submittals:
5-1.4.4.1 Drawings: Furnish two clearly legible photographic or
xerographic copies of all shop drawings that are necessary to complete the structure in
compliance with the design shown on the plans. Prepare all shop drawings using the same
units of measure as those used in the Department's plans. Use sheets no larger than II by
17 inches. Consecutively number each sheet in the submittal series, and indicate the total
number in the series (i.e., I of 12,2 of 12, . . ., 12 of 12). Include on each sheet the
following items as a minimum requirement: the complete Financial Project Identification
Number, Bridge Number(s), drawing title and number, a title block showing the names of
the fabricator or producer and the Contractor for which the work is being done, the
initials of the person(s) responsible for the drawing, the date on which the drawing was
prepared, the location of the item(s) within the project, the Contractor's approval stamp
with date and initials, and, when applicable, the documents shall be signed and sealed by
the Specialty Engineer or Contractor's Engineer of Record, as appropriate. Are-submittal
will be requested when any of the required information is not included.
19
'-----~,
5-1.4.4.2 Other Documents: Provide four sets of original documents
or clearly legible photographic or xerographic copies of documents other than drawings,
such as trade literature, catalogue information, calculations, and manuals. Provide sheets
no larger than II by 17 inches. Clearly label and number each sheet in the submittal to
indicate the total number of sheets in the series (i.e., I of 12,2 of 12,. . ., 12 of 12).
Provide an additional three sets of documentation for items involved with precast
prestressed components. Provide an additional two sets of documentation for items
involving structural steel components.
Prepare all documents using the same units of measure as those used in
the Department's plans. Bind and submit all documents with a Table of Contents cover
sheet. List on the cover sheet the total number of pages and appendices, and include the
complete Financial Project Identification Number, a title referencing the submittal
item(s), the name of the firm and person(s) responsible for the preparation of the
document, the Contractor's approval stamp with date and initials, and, when applicable,
the documents shall be signed and sealed by the Specialty Engineer or Contractor's
Engineer of Record, as appropriate.
Submit appropriately prepared and checked calculations and manuals
that clearly outline the design criteria. Include on the internal sheets the complete
Financial Project Identification Number and the initials of the person(s) responsible for
preparing and checking the document.
Clearly label trade literature and catalogue information on the front
cover with the title, Financial Project Identification Number, date and name of the firm
and person( s) responsible for that document.
5-1.4.5 Submittal Paths and Copies:
5-1.4.5.1 General: Shop drawings are not required for prequalified
items. For non-prequalified items, detennine the submittal path to be followed based
upon the identity of the Engineer of Recard as shown adjacent to the title block on the
structural plan sheets, and
on the key sheets of roadway plans, signing, and pavement marking plans, and/or lighting
plans. At the preconstruction conference, the Department will notifY the Contractor of
any changes in the submittal path and whether the Department's or the Consultant's red-
ink review stamp will signifY an officially reviewed shop drawing.
(a) When the Florida Department of Transportation is the Engineer
of Record, submit shop drawings to the appropriate Department Shop Drawing Review
Office with a copy of the letter of transmittal scnt to the Resident Engineer. Far work
requiring other information (e.g., catalog data, procedure manuals, fabrication/welding
procedures, and maintenance and operating procedures), submit the required number of
copies to the appropriate Department Shop Drawing Review Office. If not shown on the
plans, the Department will furnish the mailing address ofthe appropriate Department
Shop Drawing Review Otllce. Provide copies of material certifications and material tests
to the Resident Engineer.
(b) When the Engineer of Record is a consultant hired by the
Department, submit shop drawings to the consultant with a copy of the letter of
transmittal sent to the Resident Engineer and, when requested, to the appropriate
Department Shop Drawing Review Office. For work rcquiring other documentation (e.g.,
20
catalog data, procedure manuals, fabrication/welding procedures, and maintenance and
operating manuals), submit the required number of copies with the prints. If not shown on
the plans, the Department will furnish the mailing address ofthe Consulting Engineer of
Record. Provide copies of material certifications and material tests to the Resident
Engineer.
5-1.4.5.2 Building Structures: Submit working, shop and erection
drawings, and all correspondence related to building structures, such as Rest Area
Pavilions, Office Buildings, and Maintenance Warehouses, to the Architect of Record for
review and approval. Send a copy of the transmittal to the Resident Engineer.
5-1.4.5.3 Contractor-Originated Design: Submit shop drawings and
applicable calculations to the Engineer of Record for review. Ensure that each sheet of
the shop drawings and the cover sheet of the calculations are signed and sealed by the
Specialty Engineer or the Contractor's Engineer of Record. Transmit the submittal and
copies of the transmittal letters in accordance with the requirements of 5-1.4.5.1 through
5-1.4.5.3, as appropriate.
5-1.4.5.4 Temporary Works: For Construction Affecting Public
Safety, submit to the Engineer of Record shop drawings and the applicable calculations
for the design of special erection equipment, falsework, scaffolding, etc. Ensure that each
sheet of the shop drawings and the cover sheet of the applicable calculations is signed
and sealed by the Specialty Engineer. Transmit the submittal and copies of the transmittal
letters in accordance with the requirements of5-1.4.5.1 through 5-1.4.5.3, as appropriate.
5-1.4.5.5 Formwork and Scaffolding: The Contractor is solely
responsible for the safe installation and use of all formwork and scaffolding. The
Department does not require any formwork or scaffolding submittals unless such work
would be classified as Construction Affecting Public Safety.
5-1.4.5.6 Other Miscellaneous Design and Structural Details
Furnished by the Contractor in Compliance with the Contract: Submit to the
Engineer of Record shop drawings and the applicable calculations. Ensure that each sheet
ofthe shop drawings and the cover sheet of the applicable calculations is signed and
sealed by the Specialty Engineer. Transmit the submittal and copies of the transmittal
letters in accordance with the requirements of 5-104.5.1 through 5-104.5.3, as appropriate.
21
.--_....'
5-1.4.6 Processing of Shop Drawings:
5-1.4.6.1 Contractor Responsibility for Accuracy and
Coordination of Shop Drawings: Coardinate, schedule, and control all submittals, with
a regard for the required priority, including those of the various subcontractors, suppliers,
and engineers, to provide for an orderly and balanced distribution of the work.
Coordinate, review, date, stamp, approve and sign all shop
drawings prepared by the Contractor or agents (subcontractor, fabricator, supplier, etc.)
prior to submitting them to the Engineer of Record for review. Submittal of the drawings
confirms verification of the work requirements, units of measurement, field
measurements, construction criteria, sequence of assembly and erection, access and
clearances, catalog numbers, and other similar data. Indicate on each series of drawings
the specification section and page or drawing number of the Contract plans to which the
submission applies. Indicate on the shop drawings all deviations from the Contract
drawings and itemize all deviations in the letter of transmittal. Likewise, whenever a
submittal does not deviate from the Contract plans, clearly state so in the transmittal
letter.
Schedule the submission of shop drawings to allow for a 45 day review period.
The review period commences upon the Engineer of Record's receipt of the valid
submittal or re-submittal and terminates upon the transmittal of the submittal back to the
Contractor. A valid submittal includes all the minimum requirements outlined in 5-10404.
Allow 30 day review time for resubmittals.
Submit shop drawings to facilitate expeditious review. The Contractor is
discouraged from transmitting voluminous submittals of shop drawings at one time. For
submittals transmitted in this manner, allow for the additional review time that may
result.
Only shop drawings distributed with the "red ink" stamps are valid and all work
that the Contractor performs in advance of approval will be at the Contractor's risk.
5-1.4.6.2 Scope of Review by Engineer: The Engineer of Record's
review of the shop drawings is for conformity to the requirements of the Contract
Documents and to the intent of the design. The Engineer of Record's review of shop
drawings which include means, methods, techniques, sequences, and construction
procedures are limited to the effects on the permanent works. The Engineer of Record's
review of submittals which include means, methods, techniques, sequences, and
construction procedures does not include an indepth check for the ability to perform the
work in a safe or efficient manner. Review by the Engineer of Record does not relieve the
Contractor of responsibility for dimensional accuracy to ensure field fit and for
conformity of the various components and details.
5-1.4.6.3 Special Review by Engineer of Shop Drawings for
Construction Affecting Public Safety: For Construction Affecting Public Safety, the
Engineer of Record, or other Engineer as thc Department appoints for this purpose, will
make an independent review of all relevant shop drawings and similar documents. Do not
proceed with construction of the permanent works until receiving the Engineer of
Record's approval. The review ofthese shop drawings is for overall structural adequacy
of the item to support the imposed loads and does not include a check for economy,
efficiency or ease of construction.
22
5-1.4.7 Other Reqnirements for Shop Drawings for Bridges:
5-1.4.7.1 Shop Drawings for Structural Steel and Miscellaneous
Metals: Furnish shop drawings for structural steel and miscellaneous metals. Shop
drawings shall consist of working, shop, and erection drawings, welding procedures, and
other working plans, showing details, dimensions, sizes of material, and other
information necessary for the complete fabrication and erection of the metal work.
5-1.4.7.2 Shop Drawings for Concrete Structures: Furnish shop
drawings for concrete components that are not cast-in-place and are not otherwise
exempted from submittal requirements. Also, furnish shop drawings for all details that
are required for the effective prosecution of the concrete work and are not included in the
Contract Documents such as: special erection equipment, masonry layout diagrams, and
diagrams for bending reinforcing steel, in addition to any details required for concrete
components for the permanent work.
5-1.4.7.3 Shop Drawings for Major and Unusual Structures: In
addition to any other requirements, within 60 days from the Notice to Proceed, submit
information to the Engineer outlining the integration of the Major and Unusual Structure
into the overall approach to the project. Where applicable to the project, include, but do
not limit this information to:
(I) The overall construction program for the duration of the
Contract. Clearly show the Milestone dates. (For example, the need to open a structure by
a certain time for traffic operations.)
(2) The overall construction sequence. The order in which
individual structures are to be built, the sequence in which individual spans of girders or
cantilevers are erected, and the sequence in which spans are to be made continuous.
(3) The general location of any physical obstacles to construction
that might impose restraints or otherwise affect the construction, and an outline of how to
deal with such obstacles while building the structure(s). (For example, obstacles might
include road, rail and waterway clearances, temporary diversions, transmission lines,
utilities, property, and the Contractor's own temporary works, such as haul roads,
cofferdams, plant clearances and the like.)
(4) The approximate location of any special lifting equipment in
relation to the structure, including clearances required for the operation of the equipment.
(For example, crane positions, operating radii and the like.)
(5) The approximate location of any temporary falsework, and the
conceptual outline of any special erection equipment. Provide the precise locations and
details of attachments, fixing devices, loads, etc. in later detailed submittals.
(6) An outline of the handling, transportation, and storage of
fabricated components, such as girders or concrete segments. Provide the precise details
in later detailed submittals.
(7) Any other information pertinent to the proposed scheme or
intended approach.
Clearly and concisely present the above information on as few
drawings as possible in order to provide an overall, integrated summary of the intended
approach to the project. The Department will use these drawings for information, review
planning, and to assess the Contractor's approach in relation to the intent of the original
design. The delivery to and receipt by the Engineer does not constitute any Department
23
~,_..-
acceptance or approval of the proposals shown thereon. Include the details of such
proposals on subsequent detailed shop drawing submittals. Submit timely revisions and
re-submittals for all variations from these overall scheme proposals.
5-1.4.8 Modifications for Construction: Where the Engineer allows
the Contractor to make modifications to the permanent works for the purposes of
expediting the Contractor's chosen construction methods, the Contractor shall submit
proposals to the Engineer of Record for review and approval prior to modifYing the
works. Submit proposals for minor modifications under the shop drawing process.
Indicate on all drawings the deviations from the Contract Documents and itemize all
deviations in the letter of transmittal. The Department will require additional submittals
and/or submittal under a Value Engineering Change Proposal for major modifications.
Minor modifications are those items that, in the opinion of the
Engineer, do not significantly affect the quantity of measured work, or the integrity or
maintainability of the structure or its components. (For example, adjusting concrete
dimensions, substituting steel plate sizes, changing reinforcing bar size and spacing, etc.,
all within the acceptable limits of the design.)
Major modifications are any modifications that, in the opinion of the
Engineer, significantly affect the quantity of measured work, or the integrity ar
maintainability of the structure or its' components. (For example, substituting alternative
beam sizes and spacings, changing material strength or type, and the like.)
Provide signed and sealed revised sheets to the Engineer for any required
revisions to the Contract plans prior to submitting shop drawings.
The Engineer's decision on the delineation between a minor and a major
modification and the disposition of a proposal is final.
5-1.4.9 Cost of Shop Drawings: Include the cost of furnishing shop
and working drawings in the Contract prices for the work requiring the shop and working
drawings. The Department will not pay the Contractor additional compensation for such
drawings.
5-l.5 Certifications:
5-1.5.1 Special Erection Equipment: Prior to its use, ensure that the
Specialty Engineer personally inspects the special erection equipment and certifies to the
Engineer in writing that the equipment has been fabricated in accordance with the
submitted drawings and calculations. In addition, after assembly, ensure that the
Specialty Engineer observes the equipment in use and certifies to the Engineer in writing
that it is being used as intended and in accordance with the submitted drawings and
calculations. In each case, ensure that the Specialty Engineer also signs and seals the
letter of certification.
5-1.5.2 Falsework and Shoring Requiring Shop Drawings: After its
erection or installation but prior to the application of any superimposed load, ensure that
the Specialty Engineer personally inspects the falsework and certifies to the Engineer in
writing that the falsework has been constructed in accordance with the materials and
details shown on the submitted drawings and calculations. Ensure that the Specialty
Engineer also signs and seals the letter of ccrtification.
5-1.5.3 Temporary Formwork: For Construction Affecting Public
Safety and far Major and Unusual Structurcs, prior to the placement of any concrete,
ensure that the Specialty Engineer inspects the form work and certities to the Engineer in
24
writing that the formwork has been constructed to safely withstand the superimposed
loads to which it will be subjected. Ensure that the Specialty Engineer signs and seals the
letter of certification.
5-1.6 Corrections for Construction Errors: For work that the Contractor
constructs incorrectly or does not meet the requirements of the Contract Documents, the
Contractor has the prerogative to submit an acceptance proposal to the Engineer for
review and disposition. The acceptance proposal shall describe the error or defect and
either describe remedial action for its correction or propose a method for its acceptance.
In either case, the acceptance proposal shall address structural integrity, aesthetics,
maintainability, and the effect on Contract Time. The Department will judge any such
proposal for its effect on these criteria and also for its effect on Contract Administration.
When the Engineer judges that a proposal infringes on the structural
integrity or maintainability of the structure, the Contractor's Engineer of Record will
perform a technical assessment and submit it to the Engineer for approval. Do not take
any corrective action without the Engineer's approval.
Carry out all approved corrective construction measures at no expense to the Department.
Notwithstanding any disposition of the compensation aspects of the
defective work, the Engineer's decision on the technical merits of a proposal is final.
5-2 Coordination of Technical Documents. In cases of discrepancy, the governing
order ofthe technical documents is as follows:
I. Technical Special Provisions.
2. Plans.
3. Road Design, Structures, and Traffic Operations Standards.
4. Standard Specifications. (FDOT Div.II and Div.III)
Computed dimensions govern over scaled dimensions.
5-3 Conformity of Work with Contract Documents.
Perform all work and furnish all materials in reasonably close conformity with the
lines, grades, cross-sections, dimensions, and material requirements, including tolerances,
as specified in the Contract Documents.
In the event that the Engineer finds that the Contractor has used material or
produced a finished product that is not in reasonably close conformity with the Contract
Documents, but that the Contractor has produced reasonably acceptable work, the
Engineer will determine if the Department will accept the work in place. In this event, the
Engineer will document the basis of acceptance by Contract modification, which provides
for an appropriate reduction in the Contract price for such work or materials included in
the accepted work as deemed necessary to conform to the determination based on
engineering judgment.
In the event that the Engineer finds that the Contractor has used material or
produced a finished product that is not in reasonably close conformity with the Contract
Documents, and that the Contractor has produced an inferior or unsatisfactory product,
the Contractor shall remove and replace or otherwise correct the work or materials at no
expense to the Department.
25
.>-'-'.'-
For base and surface courses, the Department will allow the finished grade to vary
as much as 0.1 foot from the grade shown in the plans, provided that the Contractor's
work meets all templates and straightedge requirements and contains suitable transitions.
5-4 Omitted Entirely (Errors or Omissions in Contract Documents)
5-5 Authority of the Engineer.
Perform all work to the satisfaction of the Engineer.
The Engineer will decide all questions, difficulties, and disputes, of whatever
nature, that may arise relative to the interpretation of the plans, construction, prosecution,
and fulfillment of the Contract, and as to the character, quality, amount, and value of any
work done, and materials furnished, under or by reason of the Contract.
5-6 Authority and Duties of Engineer's Assistants.
The Engineer may appoint such assistants and representatives as he desires. These
assistants and representatives are authorized to inspect all work done and all materials
furnished. Such inspection may extend to all or any part of the work and to the
manufacture, preparation, or fabrication of the materials to be used. Such assistants and
representatives are not authorized to revoke, alter, or waive any requirement of these
Specifications. Rather, they are authorized to call to the attention of the Contractor any
failure of the work or materials to meet the Contract Documents, and have the authority
to reject materials or suspend the work until any questions at issue can be referred to and
decided by the Engineer. The Engineer will immediately notify the Contractor in writing
of any such suspension of the work, stating in detail the reasons for the suspension. The
presence of the inspector ar other assistant in no way lessens the responsibility of the
Contractor.
5-7 Engineering and Layout.
5-7.1 Control Points Furnished by the Department: The Engineer will provide
centerline control points (Begin Project, End Project, PIs, PTs, etc.) and bench marks at
appropriate intervals along the line of the project to facilitate the proper layout of the
work. Normally, the Engineer will furnish only one bench mark for water crossings.
Preserve all reference points and bench marks that the Department furnishes.
As an exception to the above, for projects where the plans do not show a centerline or
other survey control line for construction of the work (e.g., resurfacing, safety
modifications, etc.) the Engineer will provide only points marking the beginning and
ending of the project, and all exceptions.
5- 7.2 Furnishing of Stake Materials: Furnish all stakes, templates, and other
materials necessary for establishing and maintaining the lines and grades necessary for
control and construction of the work.
5-7.3 Layout of Work: Utilizing the control points furnished by the Department
in accordance with 5-7.1, establish all horizontal and vertical controls necessary to
construct the work in conformity to the Contract Documents. Perform all calculations
required, and set all
stakes needed such as grade stakes, offset stakes, reference point stakes, slope stakes, and
other reference marks or points necessary to provide lines and grades for construction of
all roadway, bridge, and misccllaneous items.
26
When performing utility construction as part ofthe project, establish all horizontal
and vertical controls necessary to carry out such work.
5-7.4 Specific Staking Requirements: When performing new base construction
as part of the project, set stakes to establish lines and grades for subgrade, base, curb, and
related items at intervals along the line of the work no greater than 50 feet on tangents
and 25 feet on curves. Set grade stakes at locations that the Engineer directs to facilitate
checking of sub grade, base, and pavement elevations in crossovers, intersections, and
irregular shaped areas.
For bridge construction stakes and other control, set references at sufficiently
frequent intervals to ensure construction of all components of a structure in accordance
with the lines and grades shown in the plans.
For projects where the plans do not show a centerline or other survey control line
for construction ofthe work (resurfacing, safety modifications, etc.), provide only such
stakes as necessary for horizontal and vertical control of work items.
For resurfacing and resurfacing-widening type projects, establish horizontal
controls adequate to ensure that the asphalt mix added matches with the existing
pavement. In tangent sections, set horizontal control points at 100 foot intervals by an
instrument survey. In curve sections, set horizontal control points at 25 foot intervals by
locating and referencing the centerline of the existing pavement.
Establish by an instrument survey, and mark on the surface of the finished
pavement at 25 foot intervals, the points necessary for striping of the finished roadway.
As an exception, for resurfacing and resurfacing/widening projects, establish these points
in the same manner as used for horizontal control of paving operations. Mark the
pavement with white paint. Ifperforming striping, the Engineer may approve an alternate
method for layout of striping provided that the Contractor achieves an alignment equal to
or better than the alignment that would be achieved using an instrument survey.
For projects that include temporary or permanent striping of "no passing zones",
provide the location and length of these zones as shown in the plans, except projects
where the vertical or horizontal alignment is new or altered from preconstruction
alignment. For projects that consist of new or altered vertical or horizontal alignment, the
Department will provide the location and length of the "no passing zones" during
construction. For these projects, notify the Engineer not less than 21 calendar days prior
to beginning striping.
For all projects, set a station identification stake at each right-of-way line at 100
foot intervals and at all locations where a change in right-of-way width occurs. Mark
each of these stakes with painted numerals, of a size readable from the roadway,
corresponding to the project station at which it is located. As an exception to the above,
for projects where plans do not show right-of-way lines, set station identification stakes at
locations and intervals appropriate to the type of work being done. For resurfacing and
resurfacing/widening projects, set station identification stakes at 200 foot intervals.
5-7.5 Personnel, Equipment, and Record Requirements: Employ only
competent personnel and use only suitable equipment in performing layout work. Do not
engage the services of any person or persons in the employ of the Department for
performance of layout work.
27
.....- ._--.---
Keep adequate field notes and records while performing as layout work. Make
these field notes and records available for the Engineer's review as the work progresses,
and furnish copies to the Engineer at the time of completion of the project. The
Engineer's inspection, checking, or acceptance of the Contractor's field notes or layout
wark does not relieve the Contractor of his responsibility to achieve the lines, grades, and
dimensions shown in the Contract Documents.
Prior to final acceptance of the project, mark, in a permanent manner on the
surface of the completed work, all horizontal control points originally furnished by the
Department.
5-7.6 Payment: Include the cost of performing layout work as described above in
the Contract unit prices for the various items of work that require layout.
5-8 Omitted Entirely (Contractor's Supervision)
5-9 Omitted Entirely (General Inspection Requirements)
5-10 Omitted Entirely (Final Inspection)
5-11 Omitted Entirely (Final Acceptance)
5-12 Omitted Entirely (Claims by Contractor)
5-13 Omitted Entirely (Recovery, Subsequent to Final Payment)
SECTION 6
CONTROL OF MATERIALS
6-1 Acceptance Criteria.
6-1.1 General: Acceptance of materials is based on the following criteria. All requirements may
not apply to all materials. Use only materials in the work that meet the requirements of these Specifications.
The Engineer may inspect and test any materials, at points of production, distribution and use.
6-1.2 Sampling and Testing: Use the Department's current sample identification and tracking
system to provide related information and attach such information to each sample. Restore immediately any
site from which material has been removed for sampling purposes to the pre-sampled condition with
materials and construction methods used in the initial construction, at no additional cost to the Department.
Ensure when a material is delivered to the location as described in the Contract, there is
enough material delivered to take samples, at no expense to the Department.
6-1.2.1 Pretest by Manufacturers: Submit certified manufacturer's test results to the
Engineer for qualification and use on Department projects. Testing will be as specified in the Contract
Documents. The Department may require that manufacturers submit samples of materials for independent
verification purposes.
6-1.2.2 Point of Production Test: Test the material during production as specified iu the
Contract Documents.
6-1.2.3 Point of Distribution Test: Test the material at Distribution facilities as specified
in the Contract Documents.
6-1.2.4 Point of Use Test: Test the material immediately following placement as
specified in the Specifications. After delivery to the project, the Department may require the retesting of
materials that have been tested and accepted at the source of supply, or may require the testing of materials
28
that are to be accepted by producer certification. The Department may reject all materials that, when
retested, do not meet the requirements of these Specifications.
6-1.3 Certification:
6-1.3.1 Producer Certification: Ensure completeness and correlate certification(s) of
materials provided. Furnish to the Engineer for approval, certification from the producer for all products
listed on the Department's Qualified Products List (QPL) and when required by the applicable material
Specification(s). Do not incorporate any manufactured product(s) or material(s) into the project without
approval from the Engineer. Materials will not be considered for payment when not accompanied by
Producer Certification. Producers may obtain sample certification forms through the Department's website.
Ensure that the certification is provided on the producer's letterhead and is signed by a legally responsible
person from the producer.
6-1.3.1.1 Qualified Products List: The Product Evaluation Section in the State
Specifications Office publishes and maintains a Qualified Products List (QPL). The list provides assurance
to Contractors, consultants, designers, and Department personnel that specific products and materials are
approved for use on Department facilities. The Department will limit the Contractor's use of products and
materials that require pre-approval to items listed on the QPL effective at the time of placement.
Manufacturers seeking evaluation in accordance with Departmental procedures of an item must submit a
Product Evaluation Application with a certified test report from an independent test laboratory that shows
that the material meets all applicable specifications, to the Product Evaluation Section in Tallahassee.
Manufacturers successfully completing the Department's evaluation are eligible for inclusion on the QPL.
The Department will consider any marked variations from original test values for a material or any
evidence of inadequate field performance of a material as sufficient evidence that the properties of the
material have changed, and the Department will remove the material from tbe QPL.
6-1.3.1.2 Approved Products List: The State Traffic Operations Office
maintains the Approved Products List (APL) of Traffic Control Signal Devices. Traffic Monitoring Site
Equipment and Materials are also included on the APL. This list provides assurance to Maintaining
Agencies, Contractors, consultants, designers, and Department personnel that the specific items listed are
approved for use on Department facilities. The Department will limit the Contractor's procurement and use
of Traffic Control Signal Devices, and Traffic Monitoring Site equipment and materials to only those items
listed on the APL that is effective at the time of procurement, except as provided in Section 603.
The approval process is described in detail on the State Traffic
Operation website,
www.dot.state.fl.us/trafficoperations/terl/apI2.htm .
Manufacturers seeking evaluation of a specific device must submit an
application on form number 750-010-12, which can be obtained from the Department's State Traffic
Operations Office.
6-1.3.2 Contractor Installation Certification: Provide installation certifications as
required by the Specifications.
6-2. Designation of a Specific Product as a Criterion ("Or Equal" Clause).
Reference in the Contract Documents to any proprietary article, device, product, material or
fixture, or any form or type of construction, by name, make, or catalog number, with or without the words
"or equal", establishes a standard of quality and is not intended to limit competition. The Contractor may
use any article, device, product, material or fixture, or any form or type of construction, that, in the
judgment of the Engineer (expressed in writing), is equal, for the purpose intended, to that named.
6-3 Applicable Documented Anthorities other than Specifications.
6-3.1 General: Details on individual materials are identified in various material specific Sections
of the Specifications. These Specifications may refer to other documented authorities for requirements.
When specified, meet the requirements as defmed in such references.
6-3.2 Test Methods: Methods of sampling and testing materials are in accordance with the
Florida Methods (FM). If a Florida Method does not exist for a particular test, perform the testing in
accordance with the method specified in the Specification. When test methods or other standards are
referenced in the Specifications without identification of the specific time of issuance, use the most current
issuance, including interims or addendums thereto, at the time of bid opening.
29
'.----"
6-3.3 Construction Aggregates: Aggregates used on Department projects must be in accordance
with Rule 14-103, FAC.
6-4 Documentation.
6-4.1 Submission of Materials Certification and Reporting Test Results: Provide certifications
prior to placement of materials. Report test results at completion of the test and meet the requirements of
the applicable Specifications.
6-4.2 Database(s): Not Applicable to Collier County.
6-4.3 Worksheets: Make available to the Department, when requested, worksheets used for
collecting test information. Ensure the worksheets as a minimum contain the following:
a. Project Identification Number.
b. Time and Date,
c. Laboratory Identification and Name,
d. Training Identification Numbers (TIN) and initials,
e. Record details as specified within the test method.
6-4.4 Retentiou: Meet the requirements of Section-I 05.
6-5 Inspections to Assure Compliance with Acceptance Criteria.
6-5.1 General: The Department is not obligated to make an inspection of materials at the source
of supply, manufacture, or fabrication. Provide the Engineer with unrestricted entry at all times to such
parts of the facilities that concern the manufacture, fabrication, or production of the ordered materials. Bear
all costs incurred in determining whether the material meets the requirements of these Specifications.
6-5.2 Quality Control (QC) Inspection: Provide all necessary inspection to assure effective QC
of the operations related to materials acceptance. This includes but is not limited to sampling and testing,
production, storage, delivery, construction and placement. Ensure that the equipment used in the production
and testing of the materials provides accurate and precise measurements in accordance with the applicable
Specifications. Maintain a record of all inspections, including but not limited to, date of inspection, results
of inspection, and any subsequent corrective actions taken.
6-5.3 Notification of Placing Order: Order materials sufficiently in advance of their
incorporation in the work to allow time for sampling, testing and inspection. Provide notification, to the
Engineer prior to placing orders for materials.
Submit to the Engineer a fabrication schedule for all items requiring commercial
inspection. before or at the pre-construction meeting These items include, but is not limited to steel bridge
components, overhead cantilevered sign supports with cantilevered arms exceeding 41 feet, moveable
bridge components or any other item identified as an item requiring commercial inspection in the Contract
Documents.
NotifY the Engineer at least 30 days before beginning any production and include a
production schedule.
6-6 Additional Requirements for Lump Sum Projects.
Prepare and submit to the Engineer a project-specific list of material items and quantities to be
used on the project as a Job Guide Schedule (JGS) in the same format as the Department's current
Sampling, Testing, and Reporting Guide (STRG), 21 calendar days prior to commencement of
Construction. Provide an up-to-date Job Guide Schedule to the Engineer with each monthly progress
estimate. The Department may not authorize payment of any progress estimate not accompanied by an up-
to-date Job Guide Schedule. Maintain the Job Guide Schedule throughout the project including the quantity
placed since the previous submittal, and total to date quantity and any additional materials placed. Do not
commence work activities that require testing until the Job Guide Schedule has been reviewed and accepted
by the Engineer. At final acceptance, submit final Job Guide Schedule that includes all materials used on
the project in the same fonnat as the monthly reports.
6-7 Personnel Qualification Programs.
Meet the requirements of Section 105 and ensure that qualifications are maintained during the course of
sampling, testing and inspection. Continued personnel qualifications are subject to satisfactory results from
the Department's Independent Assurance evaluations.
30
6-8 Quality Control Program.
6-8.1 General: Meet the requirements of the Department's approved Quality Control Program for
the production and construction of Asphalt Mix, Portland Cement Concrete (Structural), Earthwork,
Cementitious Materials, Timber, Steel and Miscellaneous Metals, Galvanized Metal Products, Prestressed
andlor Precast Concrete Products and Drainage Products. Also include transportation, storage, placement
and other related construction operations required by the Contract.
When accreditation or certification is required, make supporting documents from the two
previous inspections performed by the accrediting or certifYing agency available to the Department upon
request.
Obtain Department approval prior to beginning production. Meet and maintain the
approved QC Program requirements at all times. Production and construction of these products without the
Department's prior approval of a Quality Control Program may result in rejection of the products.
Continued approval will be subject to satisfactory results from Department evaluations, including the
Independent Assurance program. In cases of non-compliance with the approved Quality Control Program,
identifY all affected material and do not incorporate or supply to the Department projects. The following
conditions may result in suspension of a QC Program: .
a. Failure to timely supply information required.
b. Repeated failure of material to meet Standard Specification requirements.
c. Failure to take immediate corrective action relative to deficiencies in the
performance of the QC program.
d. Certifying materials that are not produced under an approved QC program for
use on Department projects.
e. Failure to correct any deficiencies related to any requirement of the QC
program, having received notice from the Department, within the amount of time defmed in the notice.
6-8.2. Producers of Asphalt Mixes, Portland Cement Concrete (Structural), Earthwork,
Cementitious Materials, Timber, Steel and Miscellaneous Metals, Galvanized Metal Products,
Prestressed and/or Precast Concrete Products and Drainage Products: Have an approved Quality
Control Program, developed in accordance with the guidelines in Section 105, during the production of
materials to be used on Department projects. In addition to meeting the requirements of Section 105, the
producers of Portland Cement Concrete will meet the requirements Chapter 9.2, Concrete Production
Facility Guidelines, of the Department's Materials Manual.
6-8.3 Prestressed Concrete Plants: Ensure that prestressed concrete plants participating in the
Department's Acceptance Program are qualified. Obtaining qualification will require a current
Precast/Prestressed Concrete Institute (PCI) certification and an approved Quality Control Plan, developed
in accordance with the guidelines specified in Section 105.
6-8.4 Quality Control Program Approval: Producers of cementhious materials and aggregates
must submit their proposed Quality Control Program to the State Materials Office for approval.
Producers of Asphalt Mixes, Portland Cement Concrete (Structural), Earthwork, Timber,
Steel and Miscellaneous Metals, Galvanized Metal Products, Prestressed andlor Precast Concrete Products
and Drainage Products must submit their proposed Quality Control Program to the local District Materials
Office for acceptance. Producers located outside the State must contact the State Materials Office for
address information of the District Materials Office responsible for the review of the proposed Quality
Control Program.
Steel and Miscellaneous Metal products are steel bridge components, movable bridge
components, overhead cantilevered sign supports, ladders and platforms, bearings, end wall grates,
roadway gratings, metal drainage components, steel expansion joint and components, shear connectors,
pipe handrails, galvanized steel woven wire farm fence, and guardrail.
The Department will respond to the producer within 21 calendar days of receipt of the
proposed Quality Control Program. The Department may perform evaluation activities to verifY compliance
with submitted documents prior to acceptance.
If the Quality Control Program must be revised for any reason, including non-
compliance, submit the revision to the Department. The Department will respond to the producer within 7
calendar days of receipt of the revised Quality Coutrol Program.
31
, _.,w.,_,.~,,_
6-8.5 Contractor's Quality Control Plan. Have an approved Quality Control Plan meeting the
requirements of Section 105 for the transportation, storage, placement, and other related construction
operations required by the Contract.
6-9 Lab Qualification Program.
Testing Laboratories participating in the Department's Acceptance Program must meet one of the
following requirements. In addition to the following they must have current Department qualification when
testing materials that are used on Department projects:
a. Current AASHTO (AAP) accreditation.
b. Inspected on a regular basis per ASTM D 3740 for earthwork, ASTM D 3666 for
asphalt and ASTM C 1077 for concrete for test methods used in the Acceptance Program, with all
deficiencies corrected, and under the supervision of a Specialty Engineer.
c. Current Construction Materials Engineering Council (CMEC) program accreditation or
other independent inspection program accreditation acceptable to the Engineer and equivalent to a. or b.
above.
After meeting the criteria described above, submit a Laboratory Qualification Application to the
Department. The application is available from the Department's website. Obtain the Department's
qualification prior to beginning testing. The Department may inspect the laboratory for compliance with the
accreditation requirements prior to issuing qualification.
Meet and maintain the qualification requirements at all times. Testing without Department's
qualification may result in a rejection of the test results. Continued qualifications are subject to satisfactory
results from Department evaluations, including Independent Assurance evaluations. In case of suspension
or disqualification, prior to resumption of testing, resolve the issues to the Department's satisfaction and
obtain reinstatement of qualification. The following conditions may result in suspension of a laboratory's
qualified status:
a. Failure to timely supply required information.
b. Loss of accredited stalus.
c. Failure to correct deficiencies in a timely manner.
d. Unsatisfactory performance.
e. Changing the laboratory's physical location.
f. Delays in reporting the test data in the Department's database.
g. Incomplete or inaccurate reporting.
h. Using unqualified technicians performing testing.
It is prohibited for a non-Department laboratory to perform Contractor Quality Control testing and
any other Acceptance Program testing on the same contract.
6-10 Storage of Materials and Samples.
6- I 0.1 Method of Storage: Store materials in such a manner as to preserve their quality and
fitness for the work, to facilitate prompt inspection, and to minimize noise impacts on sensitive receivers.
More detailed specifications concerning the storage of specific materials are prescribed under the
applicable Specifications. The Department may reject improperly stored materials.
6-10.2 Use of Right-of-Way for Storage: If the Engineer allows. the Contractor may use a
portion of the right-of-way for storage purposes and for placing the Contractor's plant and equipment. Use
only the portion of the right-of-way that is outside the clear zone, which is the portion not required for
public vehicular or pedestrian traveL When used, restore the right-of-way to pre-construction condition at
no additional cost to the Department or as specified in the contract. Provide any additional space required at
no expense to the Department.
6-10.3 Responsibility for Stored Materials: Accept responsibility for the protection of stored
materials. The Department is not liable for any loss of materials, by theft or otherwise, or for any damage to
the stored materials.
6-10.4 Storage Facilities For Samples: Provide facilities for storage of samples as described in
the contract and warranted by the test methods and Specifications.
32
6-11 Defective Materials.
All materials not meeting the requirements of these Specifications; segregated materials, even
though previously tested and approved; materials that are or have been improperly stored; and materials
that are mixed with an excess of clay, coal, sticks, burlap, hay, straw, loam or earth, or other debris will be
considered defective. Do not use defective materials. The Engineer will reject all such materials, whether in
place or not. Remove all rejected material immediately from the site of the work and from storage areas, at
no expense to the Department.
Do not use material that has been rejected and the defects corrected, until the Engineer has
approved the material's use. Upon failure to comply promptly with any order of the Engineer made under
the provisions of this Article, the Engineer will remove and replace defective material and deduct the cost
of removal and replacement from any moneys due or to become due the Contractor.
As an exception to the above, the Contractor may submit, upon approval of the Engineer, an
engineering and/or laboratory analysis to evaluate the effect of defective in place materials. A Specialty
Engineer, who is an independent consultant or the Contractor's Engineer of Record as stated within each
individual Section shall perform any such analysis. The Engineer will determine the fmal disposition of the
material after review of the information submitted by the Contractor. No additional monetary compensation
or time extension will be granted for the impact of any such analysis or review.
SECTION 7
LEGAL REQUIREMENTS AND
RESPONSIBILITY TO THE PUBLIC
7-1 Omitted Entirely (Laws to be Observed)
7-2 Permits and Licenses.
7-2.1 General: Except for permits procured by the Department, as incorporated
by Special Provision expanding this Subarticle, if any, procure all permits and licenses,
pay all charges and fees, and give all notices necessary and incidental to the due and
lawful prosecution of the work.
The Department will also acquire any modifications or revisions to an original
permit incorporated by Special Provision to this Subarticle when the Contractor requires
such modifications or revisions to complete the construction operations specified in the
plans or Special Provisions and within the right-of-way limits.
Acquire all permits for work performed outside the right-of-way or easements for
the project.
In carrying out the work in the Contract, when under the jurisdiction of any
environmental regulatory agency, comply with all regulations issued by such agencies
and with all general, special, and particular conditions relating to construction activities
of all permits issued to the Department as though such conditions were issued to the
Contractor. Post all permit placards in a protected location at the worksite.
In case of a discrepancy between any permit condition and other Contract Documents, the
more stringent condition shall prevail.
7-2.2 Work or Structures in Navigable Waters of the U.S., Waters of the U.S.,
and Waters of the State: In general, one or more governmental agencies will exercise
regulatory authority over work or structures, including related construction operations, in
all tidal areas (Channelward of the mean high water lines on the Atlantic and Gulf Coast);
in the ocean and gulf waters to the outer limits of the continental shelf; in all rivers,
33
_w._,_.._~,
streams, and lakes to the ordinary high water line; in marshes and shallows that are
periodically inundated and normally characterized by aquatic vegetation capable of
growth and reproduction; in all artificially created channels and canals used for
recreational, navigational, or other purposes that are connected to navigable waters; and
in all tributaries of navigable waters up to their headwaters.
Whenever the work under or incidental to the Contract requires structures or
dredge/fill/construction activities in "Navigable Waters of the U.S.," "Waters ofthe
U.S.," and "Waters of the State," the Federal, State, county, and local regulatory agencies
may require the Department to obtain a permit. For such dredge/fill /construction
specified in the plans to be accomplished within the limits of the project, or for any
dredge/fill/construction within the limits of Department-furnished borrow areas, the
Department will procure the necessary permits prior to advertising for bids.
7-3 Patented Devices, Materials and Processes.
Include all royalties and costs arising from patents, trademarks, and copyrights, in
any way involved in the work in the Contract price. Whenever using any design, device,
material, or process covered by letters patent or copyright, obtain the right for such use
by suitable legal agreement with the patentee or owner of the copyright. File a copy of
such agreement with the Engineer. However, whether or not such agreement is made or
filed as noted, the Contractor and the surety in all cases shall indemnify, defend, and save
harmless, the Department from all claims for infringement by reason of the use of any
such patented design, device, material, or process on work under the Contract, and shall
indemnifY the Department for all costs, expenses, and damages that it may be obliged to
pay by reason of any such infringement, at any time during the prosecution or after the
completion of the work.
7-4 Omitted Entirely (Right-of-Way Furnished by the Department)
7-5 Restoration of Surfaces Opened by Permit.
Upon the presentation of a duly authorized and satisfactory permit that provides
that all necessary repair work will be paid for by the party holding such permit, the
Engineer may authorize the Contractor to allow parties bearing such permits to make
openings in the highway. Upon the Engineer's written order, perform, in an acceptable
manner, all necessary repairs due to such openings, and such necessary work that the
Engineer orders, subject to the same conditions as the original work performed. The
Department will pay the Contractor for such work either under applicable Contract items
or terms.
7-6 Sanitary Provisions.
The Contractor shall provide and maintain, in a neat and sanitary condition, such
accommodations for the use of his employees as are necessary to comply with the
requirements and regulations of the State and local boards of health. Commit no public
.
nUIsance.
7-7 Control of the Contractor's Equipment.
7-7.1 Traffic Interference: Do not allow equipment, while it is on or traversing a
road or street, to unreasonably interfere with traffic.
34
7-7.2 Overloaded Equipment: Do not operate on any road or street any hauling
unit or equipment loaded in excess of (I) the maximum weights specified in the Florida
Uniform Traffic Control Law, or (2) lower weights legally established for any section of
road or bridge by the Department ar local authorities. The governmental unit having
jurisdiction over a particular road or bridge may provide exceptions by special permit
under the provisions of 7 - 7.3. This restriction applies to all roads and bridges inside and
outside the Contract limits as long as these roads and bridges are open for public use. The
Contractor may overload roads and bridges which are to be demolished after they are
permanently closed to the public. The Contractor is responsible for all loss or damages
resulting from equipment operated on a structure permanently closed to the public.
7-7.3 Crossings: Where it is necessary to cross an existing road or street,
including specifically the existing traveled lanes of a divided highway within the limits of
the project, obtain permits from the Department, for crossing overloaded or oversized
equipment. Cross existing roads or streets only at Engineer-designated points. The
Engineer may require the Contractor to protect the pavement or Roadway at the crossing
by using lumber, planks, or fill. Provide flagging and watchman service, or approved
signal devices, for the protection of traffic at all such crossings, in accordance with an
approved written plan for that activity.
7-7.4 Protection from Damage by Tractor-Type Equipment: Take positive
measures to ensure that tractor-type equipment does not damage the road. If any such
damage should occur, repair it without delay, at no expense to the Department and
subject to the Engineer's approval.
7-7.5 Contractor's Equipment on Bridge Structures: The Specialty Engineer
shall analyze the effect of imposed loads on bridge structures, within the limits of a
construction contract, resulting from the following operations:
(1) Overloaded Equipment as defined in 7-7.2:
(a) Operating on or crossing over completed bridge structures.
(b) Operating on or crossing over partially completed bridge structures.
(2) Equipment within legal load limits:
(a) Operating on or crossing over partially completed bridge structures.
(3) Construction cranes:
(a) Operating on completed bridge structures.
(b) Operating on partially completed bridge structures.
Any pipe culvert(s) or box culvert(s) qualifYing as a bridge under 1-3 is excluded
from the requirements above.
A completed bridge structure is a bridge structure in which all elemental components
comprising the load carrying assembly have been completed, assembled, and connected
in their final position. The components to be considered shall also include any related
members transferring load to any bridge structure.
The Specialty Engineer shall determine the effect that equipment loads have on
the bridge structure and develop the procedures for using the loaded equipment without
exceeding the structure's design load capacity.
Submit to the Department for approval eight copies of design calculations, layout
drawings, and erection drawings showing how the equipment is to be used so that the
bridge structure will not be overstressed. The Specialty Engineer shall sign and seal one
35
--,..-.-......
set of the eight copies of the drawings and the cover sheet of one of the eight copies of
the calculations for the Department's Recard Set.
7-7.6 Posting ofthe Legal Gross Vehicular Weight: Display the maximum
legal gross weight, as specified in the Florida Uniform Traffic Code, in a permanent
manner on each side of any dump truck or dump type tractor-trailer unit hauling
embankment material, construction aggregates, road base material, or hot bituminous
mixture to the project over any public road or street. Display the weight in a location
clearly visible to the scale operator, in numbers that contrast in color with the background
and that are readily visible and readable from a distance of 50 feet.
7-8 Structures over Navigable Waters.
7-8.1 Compliance with Federal and Other Regulations: Where erecting
structures in, adjacent to, or over, navigable waters, observe all regulations and
instructions of Federal and other authorities having control over such waters. Do not
obstruct navigation channels without permission from the proper autharity, and provide
and maintain navigation lights and signals in accardance with the Federal requirements
for the protection of the structure, of false work, and of navigation.
In the event of accidental blocking of the navigation channel, immediately notifY the U.S.
Coast Guard of the blockage and upon removal of the blockage.
When work platforms are indicated in the permit for construction, submit work platform
construction plans to the appropriate Coast Guard District for approval. Obtain approval
prior to beginning construction on the platform.
7-8.2 Maintenance of Channel: Where the work includes the excavation of a
channel or other underwater areas to a required section, maintain the section from
shoaling or other encroachment until final acceptance of the project.
7-9 Use of Explosives.
When using explosives for the prosecution of the work, exercise the utmost care
not to endanger life or property, including new work. The Contractor is responsible for all
damage resulting from the use of explosives.
Store all explosives in a secure manner in compliance with all laws and
ordinances, and clearly mark all such storage places with the words: "DANGEROUS -
EXPLOSIVES". Place such storage in the care of a competent watchman. Where no local
laws or ordinances apply, provide storage satisfactory to the Engineer and, in general, not
closer than 1,000 feet from the road or from any building, camping area, or place of
human occupancy.
Notify each public utility company having structures in proximity to the site of
the work of the intention to use explosives. Give such notice sufficiently in advance to
enable the companies to take prccautionary steps to protcct their property from injury.
7-10 Forest Protection.
7-10.1 Compliance with State and Federal Regulations: In carrying out work
within or adjacent to State ar National forests or parks, comply with all of the regulations
of the State or Federal authority having jurisdiction, governing the protection of and the
carrying out of work in forests or parks, and observe all sanitary laws and regulations
with respect to the performance of work in these areas. Keep the areas in an orderly
condition, dispose of all refuse, and obtain permits lor the construction, installation, and
36
maintenance of any construction camps, living quarters, stores, warehouses, sanitary
facilities, and other structures; all in accordance with the requirements of the forest or
park official.
7-10.2 Prevention and Suppression of Forest Fires: Take all reasonable
precautions to prevent and suppress forest fires. Require employees and subcontractors,
both independently and at the request afforest officials, to do all reasonably within their
power to prevent and suppress forest fires. Assist in preventing and suppressing forest
fires, and make every possible effort to notifY a forest official at the earliest possible
moment of the location and extent of all fires. Extinguish the fire if practicable.
7-11 Preservation of Property.
7-11.1 General: Preserve from damage all property which is in the vicinity of or
is in any way affected by the work, the removal or destruction of which is not specified in
the plans. This applies to public and private property, public and private utilities (except
as modified by the provisions of7-11.6), trees, shrubs, crops, signs, monuments, fences,
guardrail, pipe and underground structures, and public highways (except natural wear and
tear of highway resulting from legitimate use thereof by the Contractor), etc., Whenever
the Contractor's activities damage or injure such property, immediately restore it to a
condition similar or equal to that existing before such damage occurred, at no expense to
the Department.
Protect existing bridges during the entire construction period from damage caused
by the construction operations or equipment. The Department will not require the
Contractor to provide routine repairs or maintenance for such structures. However,
immediately repair, at no expense to the Department, all damage occasioned by the
construction operations. In the event that the Contractor's construction operations result
in damage to a bridge requiring repairs, the Contractor shall make such repairs with any
equipment, materials, or labor at the Contractor's disposal prior to continuing Contract
work.
Direct special attention to the protection of all geodetic monuments, horizontal or
vertical, located within the limits of construction.
7-11.2 Failure to Restore Damaged Property: In case of failure on the part of
the Contractor to restore such property, bridge, road or street, or to make good such
damage or injury, the Engineer may, upon 48 hours notice, proceed to repair, rebuild, or
otherwise restore such property, road, ar street as may be deemed necessary, and the
Department will deduct the cost thereof from any monies due or which may become due
the Contractor under the Contract. Nothing in this clause prevents the Contractor from
receiving proper compensation for the removal, damage, or replacement of any public or
private property, not shown on the plans, that is made necessary by alteration of grade or
alignment. The Engineer will authorize such work, provided that the Contractor, or his
employees or agents, have not, through their own fault, damaged such property.
7-11.3 Contractor's Use of Streets and Roads:
7-11.3.1 On Systems Other than the State Highway System: When hauling
materials or equipment to the project over roads and bridges on the State park road
system, county road system, or city street system, and such use causes damage,
immediately, at no expense to the Department, repair such road or bridge to as good a
condition as before the hauling began.
37
.._--",---,.,,..
The Department may modifY the above requirement in accordance with any
agreement the Contractor might make with the govemmental unit having jurisdiction
over a particular road or bridge, provided that the Contractor submits written evidence of
such agreement to the Engineer.
7-11.3.2 On the State Highway System: The Department is responsible for
the repair of any damage that hauling materials to the site causes to roads outside the
limits of the project, that are either on the State highway system (roads under the
jurisdiction of the Department) or specifically designated in the plans as haul roads from
Department-furnished material pits, except in the event damage is due to failure to
comply with 7-7.2. The Contractor is responsible for all damages to any road or bridge
caused by the Contractor's failure to comply with 7-7.2.
7-11.3.3 Within the Limits of a Construction Project: The Department will
not allow the operation of equipment or hauling units of such weight as to cause damage
to previously constructed elements of the project, including but not necessarily limited to
bridges, drainage structures, base course, and pavement. Do not operate hauling units or
equipment loaded in excess of the maximum weights specified in 7-7.2 on existing
pavements that are to remain in place (including pavement being resurfaced), cement-
treated sub grades and bases, concrete pavement, any course of asphalt pavement, and
bridges. The Engineer may allow exceptions to these weight restrictions for movement of
necessary equipment to and from its worksite, for hauling of offsite fabricated
components to be incorporated into the project, and for crossings as specified in 7-7.3.
7-11.4 Traffic Signs, Signal Equipment, Highway Lighting and Guardrail:
Protect all existing roadside signs, signal equipment, highway lighting and guardrail, for
which permanent removal is not indicated, against damage or displacement. Whenever
such signs, signal equipment, highway lighting or guardrail lie within the limits of
construction, or wherever so directed by the Engineer due to urgency of construction
operations, take up and properly store the existing roadside signs, signal equipment,
highway lighting and guardrail and subsequently reset them at their original locations or,
in the case of widened pavement or roadbed, at locations designated by the Engineer.
If the Department determines that damage to such existing or permanent
installations of traffic signs, signal equipment, highway lighting or guardrail is caused by
a third party(ies), and is not otherwise due to any fault or activities of the Contractor, the
Department will, with the exception of any damage resulting from vandalism,
compensate the Contractor for the costs associated with the repairs. Repair damage
caused by vandalism at no expense to the Department.
Payment for repairs will be in accordance with 4-304.
7-11.5 Operations Within Railroad Right-of-Way:
7-11.5.1 Notification to the Railroad Company: Notify the superintendent
of the railroad company, as shown on the plans, and the Engineer at least 72 hours before
beginning any operation within the limits of the railroad right-of~way; any operation
requiring movement of employees, trucks, or other equipment across the tracks ofthe
railroad company at other than an established public crossing; and any other work that
may affect railroad operations or property.
7-11.5.2 Contractor's Responsibilities: Comply with whatever requirements
an autharized representative of the railroad company deems necessary in order to
safeguard the railroad's property and operations. The Contractor is responsible for all
38
damages, delays, or injuries and all suits, actions, or claims brought on account of
damages or injuries resulting from the Contractor's operations within or adjacent to
railroad company right-of-way.
7-11.5.3 Watchman or Flagging Services: The railroad company will
furnish protective services (i.e., watchman or flagging services) to ensure the safety of
railroad operations during certain periods of the project. The Department will reimburse
the railroad company for the cost thereof. Schedule work that affects railroad operations
so as to minimize the need for protective services by the railroad company.
7-11.6 Utilities:
7-11.6.1 Arrangements for Protection or Adjustment: Do not commence
work at points where the construction operations are adjacent to utility facilities or other
property, until making arrangements with the utility facilities to protect against damage
that might result in expense, loss, disruption of service, or other undue inconvenience to
the public or to the owners. The Contractor is solely and directly responsible to the
owners and operators of such properties for all damages, injuries, expenses, losses,
inconveniences, or delays caused by the Contractor's operations.
The Department will make the necessary arrangements with utility owners for
removal or adjustment of utilities where the Engineer determines that such removal or
adjustment is essential to the performance of the required construction. The Department
will not consider relocation or adjustment requests based on the Contractor's proposed
use of a particular method of construction or a particular type of equipment as essential to
the construction of the project ifthe Contractor could use other common methods and
equipment without relocating or adjusting the utility. The Engineer will determine the
responsibility for any such required adjustments of utilities. The Contractor shall make all
requested relocations or adjustments because of delivery to the job site of Contractor-
furnished materials, at no expense to the Department.
The Department considers relocations and adjustments (or other protection)
under the following circumstances as essential to the construction of the project:
(1) Utilities lying within the vertical and horizontal construction limits,
plus the reasonably required working room necessary for operation of equipment
normally used for the particular type of construction, all as determined by the Engineer
(and except as provided in paragraph (4) below). (In the case of overhead electrical
conductors that carry more than 400 V, a minimum of 10 feet clearance between the
conductor and the nearest possible approach of any part of the equipment is required,
except where the utility owner effects safeguards approved by OSHA.)
(2) Utilities lying within the horizontal limits of the project and within 12
inches below the ground surface or the excavation surface on which the Contractor
operates construction equipment, or within 12 inches below the bottom of any stabilizing
course specified in the plans.
(3) Utilities lying within the normal limits of excavation for underground
drainage facilities or other structures (except as provided in paragraph (4) below). Such
normal limits shall extend to side slopes along the angle of repose, as established by
sound engineering practice, unless the Contract Documents require support of the
excavation sides by sheeting or the Contractor elects to sheet such excavation for his own
.
convemence.
39
'. _"""M
(4) Where utilities cross pipe trenches transversely within the excavation
area, but not within positions from which relocation or removal is necessary, the utility
owner is responsible for providing and effecting all reasonable measures for their support
and protection during construction operations. Cooperate with the utility owner in the
owner's effecting of such support and protective measures. The Contractor is responsible
for all damage to the utility that is caused by the Contractor's neglect or failure to
cooperate or to use proper precaution in performing his work.
In the event that a temporary relocation of a utility or a particular sequence
of timing in the relocation of a utility is necessary, the Engineer will direct such
relocation so as to cause the least impediment to the overall construction operations. The
Department is not responsible for utility adjustments or temporary relocation work, or for
the conditions resulting therefrom, where such adjustments are (1) not necessitated by the
construction of the project, (2) done solely for the benefit or convenience of the utility
owner or its contractor, or the highway contractor where the Department considers his
construction procedures to be other than normal, or (3) not shown on the approved plans
for the utility relocation or the construction of the project.
7-11.6.2 Cooperation with Utility Owners: Cooperate with the owners of all
underground or overhead utility lines in their removal and rearrangement operations in
order that these operations may progress in a reasonable manner, that duplication or
rearrangement work may be reduced to a minimum, and that services rendered by the
utility owners will not be unnecessarily interrupted.
In the event of interruption of water or other utility services as a result of
accidental breakage, exposure, or lack of support, promptly notify the proper authority
and cooperate with the authority in the prompt restoration of service. If water service is
interrupted and the Contractor is performing the repair work, the Contractor shall work
continuously until the service is restored. Do not begin work around fire hydrants until
the local fire authority has approved provisions for continued service.
7-11.6.3 Utility Adjustments: Certain utility adjustments and reconstruction
work may be underway during the progress ofthe Contract. Cooperate with the various
utility construction crews who are maintaining utility service. Exercise due caution when
working adjacent to relocated utilities. The Contractor shall repair all damage to the
relocated utilities resulting from his operations at no expense to the Department. The
requirements of7-1l.l and 7-11.6.2 outline the Contractar's responsibility for of
protecting utility facilities. The Department will include in the Contract the utility
autharities who are scheduled to perform utility work on the project.
7-11.6.4 Weekly Meetings: Conduct weekly meetings on the job site with all
the affected utility companies and the Engineer in attendance to coordinate project
construction and utility relocation. Submit a list of all attendees one week in advance to
the Engineer for approval.
Provide the approved Work Progress Schedule and Work Plan for the project,
as specified in 8-3.2, to document the schedule and plan for road construction and utility
adjustments. When utility relocations no longer affect construction activities, the
Contractor may discontinue the meetings with the Engineer's approval.
7-12 Omitted Entirely (Responsibility for Damages, Claims, Etc.)
40
7-13 Omitted Entirely (Insurance)
7-14 Omitted Entirely (Contractor's Responsibility for Work)
7-15 Opening Sections of Highway to Traffic.
Whenever any bridge or section of roadway is in acceptable condition for travel,
the Engineer may direct the Contractar to open it to traffic. The Department's direction to
open a bridge or roadway does not constitute an acceptance of the bridge or roadway, or
any part thereof, or waive any Contract provisions. Perform all necessary repairs or
renewals, on any section of the roadway or bridge thus opened to traffic under
instructions from the Engineer, due to defective material or wark or to any cause other
than ordinary wear and tear, pending completion and the Engineer's acceptance of the
roadway or bridge, or other work, at no expense to the Department.
7-18 Scales for Weighing Materials.
7-18.1 Applicable Regulations: When determining the weight of material for
payment, use scales meeting the requirements of Chapter 531 of Florida Statutes,
pertaining to specifications, tolerances, and regulations, as administered by the Bureau of
Weights and Measures ofthe Florida Department of Agriculture.
7-18.2 Base for Scales: Place such scales on a substantial horizontal base to
provide adequate support and rigidity and to maintain the level of the scales.
7-18.3 Protection and Maintenance: Maintain all scale parts in proper condition
as to level and vertical alignment, and fully protect them against contamination by dust,
dirt, and other matter that might affect their operation.
7-19 Source of Forest Products.
As required by Section 255.20 of the Florida Statutes, where price and quality are equal,
and when available, use only timber, timber piling, or other forest products that are
produced and manufactured in the State of Florida. This provision does not apply to
Federal-aid projects.
7-20 Regulations of Air Pollution from Asphalt Plants.
7-20.1 General: Perform all work in accordance with all Federal, State, and local
laws and regulations regarding air pollution and burning. In particular, pay attention to
Chapters 17-2 and 17-5 of the Rules and Regulations of the Department of
Environmental Protection, and to any part ofthe State Implementation Plan applicable to
the project. See also 110-9.2 regarding burning of debris.
7-20.2 Dust Control: Ensure that excessive dust is not transported beyond the
limits of construction in populated areas. The Contractor may control dust for
embankments or other cleared or unsurfaced areas by applying water or calcium chloride,
as directed by the Engineer. Use calcium chloride in accordance with 102-5. When
included in the plans, install mulch, seed, sod, or temporary paving as early as practical.
Control dust during the storage and handling of dusty materials by wetting, covering, or
other means as approved by the Engineer.
7-20.3 Asphalt Material: Use only emulsified asphalt, unless otherwise stated in
the plans and allowed by Chapter 17-2 of the Rules and Regulations of the Department of
41
- ---- .."--" - ----_..,---.--
Environmental Protection. Store and handle asphalt materials and components so as to
minimize unnecessary release of hydrocarbon vapors.
7-20.4 Asphalt Plants: Operate and maintain asphalt plants in accordance with
Chapter 17-2 of the Rules and Regulations of the Department of Environmental
Protection. Provide the plant site with a valid permit as required under Chapter 17-2 priar
to start of work.
7-21 Dredging and Filling.
Section 370.033 of the Florida Statutes, requires that all persons, who engage in certain
dredge or fill activities in the State of Florida, obtain a certificate of registration from the
Florida Department of Environmental Protection, Tallahassee, Florida 32301, and that
they keep accurate logs and records of all such activities for the protection and
conservation of the natural resources. Obtain details as to the application of this law from
the Department of Environmental Protection.
7-20 Omitted Entirely (Available Funds)
7-23 Contractor's Motor Vehicle Registration.
The Contractor shall provide the Department with proof that all motor vehicles operated
or caused to be operated by such Contractor are registered in compliance with Chapter
320 of the Flarida Statutes. Submit such proof of registration in the form of a notarized
affidavit to the Department.
The Department will not make payment to the Contractor until the required proof of
registration is on file with the Department.
If the Contractor fails to register any motor vehicle that he operates in Florida, pursuant
to Chapter 320 of the Florida Statutes, the Department may disqualify the Contractor
from bidding, or the Department may suspend and revoke the Contractor's certificates of
qualification.
SECTION 8
PROSECUTION AND PROGRESS
8-1 Omitted Entirely (Subletting or Assigning of Contracts)
8-2 Omitted Entirely (Work Performed by Equipment-Rental Agreement) Only
applicable to federally mandated wage rates.
8-3.1 Omitted (Prosecution of Work) Compliance with Time Requirements.
8-3.2 WORKING SCHEDULE
SUBARTICLE 8-3.2 (Pages 79 and 80) is deleted and the following substituted:
8-3.2 General: For this Contract submit the following schedules and reports.
42
8-3.2.1 Contract Schedule: Submit to the Engineer for acceptance a Critical
Path Method (CPM) Contract Schedule for the project within 30 calendar days after
execution of the Contract or at the preconstruction conference, whichever is earlier.
The Contract Schedule shall include detailed schedule diagrams and
schedule data as described below for the entire Contract Period. The Contract Schedule
shall be consistent with the Contract Maintenance of Traffic plan, showing activities for
each discrete Contract activity to be accomplished within each Maintenance of Traffic
phase. Include activities for deliverables and reviews in the schedule. Sufficient liaison
shall be conducted and information provided to indicate coordination with utility owners
having facilities within the project limits. The schedule must reflect the utility adjustment
schedules included in the Contract Documents, unless changed by mutual agreement of
the utility company, the Contractor and the Department.
Failure to include any element of work or any activity relating to utility
work will not relieve the Contractor from completing all work within the Contract Time
at no additional time or cost to the Department, not withstanding the acceptance of the
schedule by the Department.
The Engineer will withhold monthly payments due for failure of the
Contractor to submit an acceptable schedule or monthly updates within the time frame
described herein.
8-3.2.2 Schednle Submissions: Develop the schedule in Precedence Diagram
Method (PDM) format. All schedule submittals, shall have a copy ofthe schedule files on
a Windows compatible 3.5" diskette or CD attached. The files shall be in one ofthe
following formats:
I. Primavera Project Planner (P3) project files using the Primavera Project
Planner (latest version) "Back up" menu selection. Ensure that the option "Remove
access list during backup": is checked.
2. Primavera Suretrak (latest version) "Back up" menu selection. Ensure
that the option "Remove access list during backup" is checked.
Each schedule submission and monthly update shall include a minimum of
4 times:
I) a CPM Network Diagram in time-scale logic diagram, by week
starting on Monday, grouped (banded) by phrase and sorted by early start days.
Prominently identify the critical path activities, defined as the longest continuous path of
work activities. Submit the Network Diagram, printed in color on D size, 22 by 34 inch
or E size, 34 by 44 inch paper. The network diagram shall contain, as a minimum, the
following information far each schedule activity: identification, activity description, total
duration, remaining duration, early start date, late finish date, and total float.
2) a report with the following schedule activity information for
each construction activity: identification, description, original duration, remaining
duration, early start, early finish, total float, percent complete, and budgeted cost. The bar
chart diagram shall not be included in this report. It will be submitted on 8.5 by 11 inch
paper.
3) a schedule narrative report describing current project schedule
status and identifYing potential delays. This report will include a description of the
progress made since the previous schedule submission and objectives for the upcoming
43
-,,-_.- ---"--'~--
30 calendar days. It will be submitted on 8.5 by II inch paper. This report shall at a
minimum include the following information:
a) This report shall indicate if the project is on schedule,
ahead of schedule or behind schedule. If the project is ahead of schedule or behind
schedule, the report shall include the specific number of calendar days. If the project is
behind schedule, the report shall include a detailed recovery plan that will put the project
back on schedule or include a properly supported request for Time Extension.
b) The report will describe the current critical path of the
project and indicate if this has changed in the past 30 calendar days. Discuss current
successes or problems that have affected either the critical path's length or have caused a
shift in the critical path within the last 30 calendar days. Identify specific activities,
progress, or events that may reasonably be anticipated to impact the critical path within
the next 30 calendar days, either to affect its length ar to shift it to an alternate path.
c) List all schedule logic or duration changes that have been
made to the schedule since the previous submission. For each change, describe the basis
for the change and specifically identify the affected activities by identification number.
d) Identify any and all activities, either in progress or
scheduled to occur within the following 30 days that require Primavera Surttrack formats
in accordance with formats specified herein.
The Engineer will have 30 days to accept the contract schedule or
to schedule a meeting with the Contractor to resolve any problems that prevent
acceptance of the schedule. Attend the meeting scheduled by the Engineer, and submit a
corrected schedule to the Engineer within seven days after the meeting. The process will
be continued until a contract schedule is accepted by the Engineer.
8-3.2.3 Schedule Content: All schedule submissions shall comply with the
following content guidelines as appropriate to the specific submission:
Outline Schedule Diagrams and Data shall show the sequence, order and
interdependence of major construction milestones and activities. Include ordering and
procurement of major materials and equipment, long-lead time items, and key milestones
identified by the Contract. Identify planned work schedule(s) and include all non-
workdays. Provide a description of each major construction activity or key milestone.
Detailed Schedule Diagrams shall include activity number, description,
early dates, float, and all relationships (i.e. logic ties), resources and costs. Show the
sequence, order, and interdepcndence of activities in which the work is to be
accomplished. Include allowance for Department oversight, acceptance and return of
submittals, samples and shop drawings where Department acceptance is specifically
required (in accordance with 5-1.4.6 of the standard specifications). In addition to
construction activities, detailed network activities shall include the submittals,
procurement, and Department or Utility activities impacting progress:
a. Submittal activities shall include oversight and acceptance of
submittals. If the Department's action on any submittal is "Not Accepted" or "Revise and
Resubmit", a new series of submittal preparation activities shall be inserted into the
schedule. Predecessor for the new submittal preparation activity will be the original
acceptance activity and the successor of the new acceptance activity will be the
fabrication/delivery activity for the equipment or material.
44
b. Procurement activities shall include all materials and equipment,
receipt of materials with estimated procurement costs of major items for which payment
of stockpiled materials will be requested in advance of installation, fabrication of special
material and equipment, and their installation and testing.
c. Show activities of the Department or Utilities that affect the
progress and contract-required dates for completion of all or parts of the work.
Detailed Schedule Data: shall conform to the following:
a. All activities shall be assigned to a specific calendar within the
software. Specific calendars will be defined within the software to include planned work
days and working hours. These calendars will include both Contractor and Contract
defined holidays and suspension days as non-workdays.
b. Each schedule activity shall be cost loaded. Activity cost loading
shall be consistent with the bid breakdown. The sum total of the activity cost loading
shall be equal to the current contract value.
c. At a minimum, each schedule activity shall contain codes by
I. Responsibility: including, but not limited to, Department,
Utility, Contractor/Subcontractor, SupplierNendor, Consultant, etc.
2. Phasing: identify the appropriate Maintenance of Traffic
phase or subphase.
d. Key milestones as identified by contract. At a minimum, the
start and finish of each Maintenance of Traffic phase or subphase shall be represented by
a milestone activity.
e. All non-procurement activities must be less than or equal to 20
workdays unless approved by the Engineer to be greater by the Engineer.
f. Detailed description of each activity. In each activity, give
quantity and unit of measure so that the amount of work the activity involves is clearly
communicated.
g. Only two (2) open-ended activities (the first and the last) are
allowed.
h. Constraints shall only be used for "Project Start," and "Project
Completion." Constraints cannot override logic. The use of any other imposed constraints
is not allowed without specific approval by the Engineer. Any other desired constraints
must be submitted to the Engineer with the rationale for the use of each desired additional
constraint. If allowed by the Engineer, the rationale should be recorded in the activity's
log field. Mandatary constraints (start and finish) violate network logic and shall not be
used.
i. Out of sequence progress, if applicable, shall be handled through
Retained Logic. Use ofthe Progress Override option is not appropriate for this project
and will not be allowed.
j. Progress shall be calculated based on percent complete.
k. All changes to activities shall be recorded with a note in the
activity log field. The log shall include, as a minimum, the date and reason for the
change, as well as reference to a document wherein the Engineer acknowledges and
accepts the change.
I. The use ofresource leveling, either manual or automatic, is
prohibited.
45
8-3.2.4 Weekly Meetings: Attend weekly meetings scheduled by the
Engineer to discuss Contract progress, near term scheduled activities, including utility
relocations, problems and their proposed solutions. Submit a Two-Week "Look Ahead"
Planning Schedule at each weekly meeting, showing the items of work planned for the
next two weeks. Develop the schedule in Bar Chart format, identifYing current and
planned activities and related Contract Schedule work activities, including subcontractor
work. Designate all activities that are controlling work items as determined by the
currently accepted Contract Schedule. A report shall be submitted at each weekly
meeting identifYing schedule activity progress including actual start or finish dates
achieved for any activities.
8-3.2.5 Float: Is also known as slack time or slide time; it is defined as the
amount oftime the finish of an activity can be delayed. Two kinds of float are possible:
Total float is how much an activity can be delayed without affecting the finish date of the
project or an intermediate deadline (constraint); it is the difference between the late fmish
date and the early finish date. Free float is how much an activity can be delayed without
affecting its earliest successor.
Float is not for the exclusive use or benefit of either the Department or the
Contractor.
Use of float suppression techniques, such as preferential sequencing
(arranging critical path through activities more susceptible to Department caused delay),
special lead/lag logic restraints, zero total or free float constraints, extended activity
times, or imposing constraint dates other than as required by the contract, shall be cause
for rejection of the project schedule or its updates. The use of Resource Leveling (or
similar softwarc features) used for the purpose of artificially adjusting activity durations
to consume float and influence the critical path is expressly prohibited.
Negative float shall not be a basis for requesting time extensions. Any
extension of time shall be addressed in accardance with 8-3.2.6 Time Extensions.
Scheduled completion date(s) that extend beyond the contract completion date (evidenced
by negative float) may be used in computations for assessment of payment withholdings.
The use of this computation is not to be construed as a means of acceleration.
8-3.2.6 Time Extensions: The Contractor is responsible for submitting a
request for Contract Time extension in accordance with 8-7.3.2 of the standard
specifications. An extension of time for performance shall be considered only to the
extent that a delay to an activity or activities exceeds the total float along the project
critical paths.
As a minimum, time extension requests shall contain:
a. A descriptive summary of the changes
b. An analysis of project impact
c. A fragnet that shows the impacted activities before the change.
d. A fragnet that shows the impacted activities after the change.
Time extensions shall not be considered for proposals that do not include
full documentation tor the schedule change. Once a change has been approved by the
Engineer, the specific activities and the overall schedule must be updated.
8-3.2.7 Performance of Work: By submitting a schedule the Contractor is
making a positive assertion that the project will be constructed in the order indicated on
the schedule. Prosecute the work in accordance with thc latcst accepted Working
46
Schedule. Any costs associated with meeting milestones and completing the project
within the authorized Contract Time will be borne solely by the Contractor.
8-3.2.8 As-Built Schedule: As a condition for the release of any retainage,
submittal of an as-built schedule which describes the actual order and start and stop times
for all activities by the Contractor is required.
8-3.3 Omitted Entirely (Beginning Work)
8-3.4 Omitted Entirely (Provisions for Convenience of Public
8-3.5 Omitted Entirely (Preconstruction Conference)
8-3.6 P ARTNERING
SUBARTICLE 8-3.6 is inserted:
8-3.6 Partnering: For this Contract, a non-bid pay item in the Lump Sum amount
of $5,000.00 has been established for Partnering. The objective of Partnering is to
establish a partnership charter and action plan for the Contractor, the Engineer and other
parties impacted by the activities covered under this Contract to identifY and achieve
reciprocal goals. These objectives may be met through participation in a major workshop
held as early as possible after the Contract is awarded and follow-up workshops held
periodically throughout the duration of the Contract.
As early as possible and prior to the preconstruction conference, meet with the
TECM Director and plan an initial partnering/team building workshop. At this planning
session, select a workshop facilitator, suitable to the TECM Director, from the FDOT
approved list offacilitators maintained by the Quality Initiatives Office. Additionally, the
agenda, duration, location, time, and attendees for the initial workshop should be
determined.
Attendees should include the TECM Director, the Project Engineer, the Road
Construction Manager, The Project Manager and key project personnel, the Contractor's
Superintendent and key personnel as well as other project or field level personnel.
Partnering workshops may be held periodically throughout the duration of the
Contract if authorized by the TECM Director. The County will reimburse the Contractor
based on actual invoice amounts for the following costs associated with Partnering:
a. Meeting room.
b. Facilitator fees.
c. Travel expenses of the facilitator, in accordance with Section 112.061,
Florida Statues.
The County will not reimburse the Contractor for any other expenses. Payment
will be the actual cost prorated as a percent of the Lump Sum amount. Payment shall be
made under: Item No. 999- 16- Partnering -lump sum.
47
8-4 Limitations of Operations.
8-4.1 Night Work: During active nighttime operations, furnish, place and
maintain lighting sufficient to permit proper workmanship and inspection. Use lighting
with 5 ft. cd minimum intensity. Arrange the lighting to prevent interference with traffic
or produce undue glare to property owners. Operate such lighting only during active
nighttime construction activities. Provide a light meter to demonstrate that the minimum
light intensity is being maintained.
Lighting may be accomplished by the use of portable floodlights, standard
equipment lights, existing street lights, temporary street lights, or other lighting methods
approved by the Engineer.
Submit a lighting plan at the Preconstruction Conference for review and approval
by the Engineer. Submit the plan on standard size plan sheets (not larger than 24 by 36
inch), and on a scale of either 100 or 50 foot to I inch. Do not start night work prior to
the Engineer's approval of the lighting plan.
During active nighttime operations, furnish, place and maintain variable message
signs to alert approaching motorists of lighted construction zones ahead. Operate the
variable message signs only during active construction activities.
Equip all pickups and automobiles used on the project with either amber flashing
2
lights or flashing white lights. Equip all other equipment with a minimum of 4 ft of
reflective sheeting, or flashing lights. To avoid distraction to motorists, do not operate the
lights on the vehicles or equipment when the vehicles are outside the clear zone or behind
traffic control devices.
Ensure that all personnel shall wear reflective vests at all times while in the work
area.
Comply with all applicable regulations governing noise abatement.
Have a Certified W orksite Supervisor on site during all nighttime operations to
ensure proper Maintenance of Traffic.
48
Include compensation for lighting for night work in the Contract prices for the
various items of the Contract. Take ownership of all lighting equipment for night work.
8-4.2 Sequence of Operations: Do not open up work to the prejudice of work
already started. The Engineer may require the Contractor to finish a section on which
work is in progress before starting work on any additional section.
8-4.3 Interference with Traffic: At all times conduct the work in such manner
and in such sequence as to ensure the least practicable interference with traffic. Operate
all vehicles and other equipment safely and without hindrance to the traveling public.
Park all private vehicles outside the clear zone. Place materials stored along the roadway
so as to cause no obstruction to the traveling public as possible.
Where existing pavement is to be widened and stabilizing is not required, prevent
any open trench from remaining after working hours by scheduling operations to place
the full thickness of widened base by the end of each day. Do not construct widening
strips simultaneously on both sides of the road, except where separated by a distance of at
least 1/4 mile along the road and where either the work of excavation has not been started
or the base has been completed.
8-4.4 Coordination with other Contractors: Sequence the work and dispose of
materials so as not to interfere with the operations of other Contractors engaged upon
adjacent work; join the work to that of others in a proper manner, in accordance with the
spirit of the Contract Documents; and perform the work in the proper sequence in relation
to that of other contractors; all as may be directed by the Engineer.
Each contractor is responsible for any damage done by him or his agents to the
work performed by another contractor.
8-4.5 Drainage: Conduct the operations and maintain the work in such condition
to provide adequate drainage at all times. Do not obstruct existing functioning storm
sewers, gutters, ditches, and other run-off facilities.
8-4.6 Fire Hydrants: Keep fire hydrants on or adjacent to the highway accessible
to fire apparatus at all times, and do not place any material or obstruction within 15 feet
of any fire hydrant.
8-4.7 Protection of Structures: Do not operate heavy equipment close enough to
pipe headwalls or other structures to cause their displacement.
8-4.8 Fencing: Erect permanent fence as a first order of business on all projects
that include fencing where the Engineer determines that the fencing is necessary to
maintain the security of livestock on adjacent property, or for protection of pedestrians
who are likely to gain access to the project from adjacent property.
8-4.9 Hazardous or Toxic Waste: When the construction operations encounter
or expose any abnormal condition that may indicate the presence of a hazardous or toxic
waste, discontinue such operations in the vicinity ofthe abnormal condition and notifY
the Engineer immediately. Be alert for the presence oftanks or barrels; discolored earth,
metal, wood, ground water, etc.; visible fumes; abnormal odors; excessively hot earth;
smoke; or other conditions that appear abnormal as possible indicators of hazardous or
toxic wastes and treat these conditions with extraordinary caution.
Make every effort to minimize the spread of any hazardous or toxic waste into
uncontaminated areas.
Do not resume the construction operations until so directed by the Engineer.
49
--- _..
Dispose of the hazardous or toxic waste in accordance with the requirements and
regulations of any Local, State, or Federal agency having jurisdiction. Where the
Contractor performs work necessary to dispose of hazardous or toxic waste, and the
Contract does not include pay items for disposal, the Department will pay for this work as
provided in 4-4.
The Department may agree to hold harmless and indemnifY the Contractor for
damages when the Contractor discovers or encounters hazardous materials or pollutants
during the performance of services for the Department when the presence of such
materials or pollutants were unknown or not reasonably discoverable. Such
indemnification agreements are only effective if the Contractor immediately stops work
and notifies the Department of the hazardous material or pollutant problem.
Such indemnification agreement are not valid for damages resulting from the
Contractor's willful, wanton, or intentional conduct or the operations of Hazardous
Material Contractors.
8-5 Omitted Entirely (Qualifications of Contractor's Personnel)
8-6 Omitted Entirely (Temporary Suspension of Contractor's Operations)
8-7 Computation of Contract Time.
8-7.1 General: Perform the contracted work fully, entirely, and in accordance
with the Contract Documents within the Contract Time specified in the proposal, or as
may be extended in accordance with the provisions herein below.
The Department considers in the computation of the allowable Contract Time the effect
that utility relocation and adjustments have on job progress and the scheduling of
construction operations required in order to adequately maintain traffic, as detailed in the
plans or as scheduled in the Special Provisions.
8-7.2 Date of Beginning of Contract Time: The date on which Contract Time
begins is either (1) the date on which the Contractor actually begins work, or (2) the date
for beginning the charging of Contract Time as set forth in the proposal; whichever is
earlier.
8-7.3 Adjusting Contract Time:
8-7.3.1 Increased Work: The Department may grant an extension of Contract
Time when it increases the Contract amount due to overruns in original Contract items,
adds new work items, or provides for Wlforeseen work. The Department will base the
consideration for granting an extension of Contract Time on the extent that the time
normally required to complete thc additional designated work delays the Contract
completion schedule.
8-7.3.2 Contract Time Extensions: The Department may grant an extension
of Contract Time when a controlling item of work is delayed by factors not reasonably
anticipated or foreseeable at the time of bid. The Department may allow such extension
of time only for delays occurring during the Contract Time period or authorized
extensions ofthe Contract Time period. When failure by the Department to fulfill an
obligation under the Contract results in delays to the controlling items of wark, the
Department will consider such delays as a basis for granting a time extension to the
Contract.
Whenever the Engineer suspends the Contractor's operations, as provided in
8-6, for reasons other than the fault of the Contractor, the Engineer will grant a time
50
extension for any delay to a controlling item of work due to such suspension. The
Department will not grant time extensions to the Contract for delays due to the fault or
negligence of the Contractor.
This is a calendar day contract and no additional time will be allowed for
weather delays except for floods, hurricanes, other force majoure or unforeseen event in
whole or part beyond the control of the Contractor, a subcontractor or material supplier.
In the event such a event occurs the following procedures In the event such an event
occurs the following procedures shall be followed to determine if any additional time is
due the contractor.
The effect of the adverse weather conditions other force majoure or
unforeseeable event which negatively impacts upon or delays the Contractor's controlling
of critical activities shall be evaluated on the date of each occurrence by the Engineer and
the Contractor's superintendent. Seasonal or unseasonal rainfall will not be considered a
viable cause for resultant impacts and delays, if any.
Contract time extensions shall not accrue nor be granted automatically during
the course of the work. Rather, the determination of whether time extensions will be
granted to the Contractor shall only occur at the completion of all Contract work, and
only if requested by the Contractor in writing. Moreover, considerations for granting
additional Contract time for rain-induced delays shall be subject to the Contractor's
submission of detailed project records including evidence of same as depicted by
pertinent time/activity information on the project schedule. Additionally, as a
prerequisite to the Engineer reviewing the Contractor's request to grant an extension of
Contract time for any reasons whatsoever, the Contractor shall provide a copy of the
Project Schedule which shall clearly indicate the dates and events contributing to the
delay(s) under consideration."
No additional compensation will be made for delays caused by the effects of
inclement weather.
The Department will consider the delays in delivery of materials or
component equipment that affect progress on a controlling item of work as a basis for
granting a time extension if such delays are beyond the control ofthe Contractor or
supplier. Such delays may include an area-wide shortage, an industry-wide strike, or a
natural disaster that affects all feasible sources of supply. In such cases, the Contractor
shall furnish substantiating letters from a representative number of manufacturers of such
materials or equipment clearly confirming that the delays in delivery were the result of an
area-wide shortage, an industry-wide strike, etc. No additional compensation will be
made for delays caused by delivery of materials or component equipment.
The Department will not consider requests for time extension due to delay in
the delivery of custom manufactured equipment such as traffic signal equipment,
highway lighting equipment, etc., unless the Contractor furnishes documentation that he
placed the order for such equipment in a timely manner, the delay was caused by factors
beyond the manufacturer's control, and the lack of such equipment caused a delay in
progress on a controlling item of work. No additional compensation will be paid for
delays caused by delivery of custom manufactured equipment.
The Department will consider the affect of utility relocation and adjustment
work on job progress as the basis for granting a time extension only if all the following
criteria are met:
51
-
(1) Delays are the result of either utility work that was not detailed in the
plans, or utility work that was detailed in the plans but was not accomplished in
reasonably close accordance with the schedule included in the Contract Documents.
(2) Utility work actually affected progress toward completion of
controlling work items.
(3) The Contractor took all reasonable measures to minimize the effect of
utility work onjob progress, including cooperative scheduling of the Contractor's
operations with the scheduled utility wark at the preconstruction conference and
providing adequate advance notification to utility companies as to the dates to coordinate
their operations with the Contractor's operations to avoid delays.
As a condition precedent to an extension of Contract Time the Contractor
must submit to the Engineer:
A preliminary request for an extension of Contract Time must be made in
writing to the Engineer within ten calendar days after the commencement of a delay to a
controlling item of work. If the Contractor fails to submit this required preliminary
request for an extension of Contract Time, the Contractor fully, completely, absolutely
and irrevocably waives any entitlement to an extension of Contract Time for that delay.
In the case of a continuing delay only a single preliminary request for an extension of
Contract Time will be required. Each such preliminary request for an extension of
Contract Time shall include as a minimum the commencement date of the delay, the
cause of the delay, and the controlling item of work affected by the delay; and
Further, the Contractor must submit to the Engineer a request for a Contract
Time extension in writing within 30 days after the elimination of the delay to the
controlling item of work identified in the preliminary request for an extension of Contract
Time. Each request for a Contract Timc extension shall include as a minimum all
documentation that the Contractor wishes the Department to consider related to the delay,
and the exact number of days requested to be added to Contract Time. If the Contractor
fails to submit this required request for a Contract Time extension, with ar without a
detailed cost analysis, depriving the Engineer of the timely opportunity to verify the
delay, the Contractor waives any entitlement to an extension of Contract Time.
Upon timely receipt of the preliminary request of Contract Time from the
Contractor, the Engineer will investigate the conditions, and if it is determined that a
controlling item of work is being delayed for reasons beyond the control of the
Contractor the Engineer will take appropriate action to mitigate the delay and the costs of
the delay. Upon timely receipt of the request for a Contract Time extension the Engineer
will further investigate the conditions, and if it is determined that there was an increase in
the time of performance of the controlling item of work beyond the control of the
Contractor, then an adjustment of Contract Time will be made, and the Contract will be
modified in writing accordingly.
The existence of an accepted schedule, is a condition precedent to the
Contractor having any right to the granting of an extension of contract time. Contractor
failure to have an accepted schedule, including any required update(s), for the period of
potential impact, or in the event the currently accepted schedule and applicable updates
do not accurately reflect the actual status of the project or fail to accurately show the true
controlling or non-controlling work activities for the period of potential impact, will
result in any entitlement determination as to time for such period of potential impact
52
being limited solely to the Department's analysis and identification of the actual
controlling or non-controlling work activities. Further, in such instances, the
Department's determination as to entitlement as to time will be final.
8-8 Omitted Entirely (Failure of Contractor to Maintain Satisfactory Progress)
Only applicable to FDOT contracts.
8-9 Omitted Entirely (Default and Termination of Contract)
8-10 Omitted Entirely (Liquidated Damages for Failure to Complete Work)
8-11 Omitted Entirely (Release of Contractor's Responsibility)
8-12 Omitted Entirely (Recovery of Damages Suffered by Third Parties)
SECTION 9
MEASUREMENT AND PAYMENT
9-1 Measurement of Quantities.
9-1.1 Measurement Standards: The Engineer will measure all work completed
under the Contract in accordance with the United States Standard Measures.
9-1.2 Method of Measurements: The Engineer will take all measurements
horizontally or vertically.
9-1.3 Determination of Pay Areas:
9-1.3.1 Final Calculation: When measuring items paid for on the basis of
area of finished work, where the pay quantity is designated to be determined by
calculation, the Engineer will use lengths and widths in the calculations based on the
station to station dimensions shown on the plans; the station to station dimensions
actually constructed within the limits designated by the Engineer; or the final dimensions
measured along the surface of the completed work within the neat lines shown on the
plans or designated by the Engineer. The Engineer will use the method or combination of
methods of measurement that reflect, with reasonable accuracy, the actual surface area of
the finished work as the Engineer determines.
9-1.3.2 Plan Quantity: When measuring items paid for on the basis of area of
finished work, where the pay quantity is designated to be the plan quantity, the Engineer
will determine the final pay quantity based on the plan quantity subject to the provisions
of9-3.2. Generally, the Engineer will calculate the plan quantity using lengths based on
station to station dimensions and widths based on neat lines shown in the plans.
9-1.4 Construction Outside Authorized Limits: The Engineer will not pay for
surfaces constructed over a greater area than authorized, or for material that the
Contractor has moved from outside of slope stakes and lines shown on the plans, except
where the Engineer provides written instruction for the Contractor to perform such work.
9-1.5 Truck Requirements: Provide all trucks with numbers and certify that all
trucks used have a manufacturer's certification or permanent decal showing the truck
53
- ,--
capacity rounded to the nearest tenth of a cubic yard placed on both sides of the truck.
This capacity will include the truck body only and any side boards added will not be
included in the certified truck body capacity. Ensure the lettering and numbers are legible
for identification purposes at all times.
9-1.6 Ladders and Instrument Stands for Bridge Projects: On bridge projects,
in order to facilitate necessary measurements, provide substantial ladders to the tops of
piers and bents, and place and move such ladders as the Engineer directs.
For bridge projects crossing water or marshy areas, supply fixed stands for instrument
mounting and measurements, in accordance with the details stipulated in the
Specifications for the project.
9-2 Scope of Payments.
9-2.1 Items Included in Payment: Accept the compensation as provided in the
Contract as full payment for furnishing all materials and for performing all work
contemplated and embraced under the Contract; also for all loss or damage arising out of
the nature of the work or from the action of the elements, or from any unforeseen
difficulties or obstructions which may arise or be encountered in the prosecution of the
work until its final acceptance; also for all other costs incurred under the provisions of
Division 1.
For any item of work contained in the proposal, except as might be specifically
provided otherwise in the basis of payment clause for the item, include in the Contract
unit price (or lump sum price) for the pay item or items the cost of all labor, equipment,
materials, tools and incidentals required for the complete item of work, including all
requirements of the Section specifying such item of work, except as specifically excluded
from such payments.
9-2.1.1 Fuels:
Refer to Supplemental Conditions - "Fuel Cost Adjustment"
9-2.1.2 Omitted in its entirety (Bituminous Material)
Replaced by Supplemental Condition - "Bituminous Cost Adjustment"
9-3 Compensation for Altered Quantities.
9-3.1 General: When alteration in plans or quantities of work not requiring a
supplemental agreement as hereinbefore provided for are offered and performed, the
Contractor shall accept payment in full at Contract unit bid prices for the actual quantities
of work done, and no allowance will be made for increased expense, loss of expected
reimbursement, or loss of anticipated profits suffered or claimed by the Contractor,
resulting either directly from such alterations, or indirectly from unbalanced allocation
among the Contract items of overhead expense on the part of the bidder and subsequent
loss of expected reimbursement therefore, or from any other cause.
Compensation for alterations in plans or quantities of work requiring
supplemental agreements shall be stipulated in such agreement, except when the
Contractor proceeds with the work without change of price being agreed upon, the
Contractor shall be paid for such increased or decreased quantities at the Contract unit
prices bid in the Proposal for the items of work. If no Contract unit price is provided in
54
the Contract, and the parties cannot agree as to a price for the work, the Contractor agrees
to do the work in accordance with 4-3.2.
9-3.2 Payment Based on Plan Quantity:
9-3.2.1 Error in Plan Quantity: As used in this Article, the term "substantial
error" is defined as the smaller of (a) or (b) below:
(a) a difference between the original plan quantity and fmal quantity of
more than 5%,
(b) a change in quantity which causes a change in the amount payable of
more than $5,000.
On multiple job Contracts, changes made to an individual pay item due to
substantial errors will be based on the entire Contract quantity for that pay item.
Where the pay quantity for any item is designated to be the original plan
quantity, the Department will revise such quantity only in the event that the Department
determines it is in substantial error. In general, the Department will determine such
revisions by final measurement, plan calculations, or both, as additions to or deductions
from plan quantities.
In the event that either the Department or the Contractor contends that the
plan quantity for any item is in error and additional or less compensation is thereby due,
the claimant shall submit, at their own expense, evidence of such in the form of
acceptable and verifiable measurements or calculations. The Department will not revise
the plan quantity solely on the basis of a particular method of construction that the
Contractor selects. For earthwork items, the claimant must note any differences in the
original ground surfaces from that shown in the original plan cross-sections that would
result in a substantial error to the plan quantity, and must be properly documented by
appropriate verifiable level notes, acceptable to both the Contractor and the Department,
prior to disturbance of the original ground surface by construction operations. The
claimant shall support any claim based upon a substantial error for differences in the
original ground surface by documentation as provided above.
9-3.2.2 Authorized Changes in Limits of Work: Where the Department
designates the pay quantity for any item to be the original plan quantity and authorizes a
plan change which results in an increase or decrease in the quantity of that item, the
Department will revise the plan quantity accordingly. In general, the Department will
determine such revisions by final measurement, plan calculations or both.
9-3.2.3 Specified Adjustments to Pay Quantities: Do not apply the
limitations specified in 9-3.2.1 and 9-3.2.2 to the following:
(1) Where these Specifications or Special Provisions provide that the
Department determines the pay quantity for an item on the basis of area of finished work
adjusted in accordance with the ratio of measured thickness to nominal thickness.
(2) Where these Specifications provide for a deduction due to test results
falling outside of the allowable specified tolerances.
(3) To payment for extra length fence posts, as specified in 550-6.3.
9-3.3 Lump Sum Quantities:
9-3.3.1 Error in Lump Sum Quantity: Where the Department designates the
pay quantity for an item to be a lump sum and the plans show an estimated quantity, the
Department will adjust the lump sum compensation only in the event that either the
Contractor submits satisfactory evidence or the Department determines and furnishes
55
----".~-
satisfactory evidence that the lump sum quantity shown is in substantial error as defined
in 9-3.2.1.
9-3.3.2 Authorized Changes in Work: Where the Department designates the
pay quantity for an item to be a lump sum and the plans show an estimated quantity, the
Department will adjust compensation for that item proportionately when an authorized
plan change is made which results in an increase or decrease in the quantity of that item.
When the plans do not show an estimated plan quantity ar the applicable specifications
do not provide adjustments for contingencies, the Department will compensate for any
authorized plan change resulting in an increase or decrease in the cost of acceptably
completing the item by establishing a new unit price through a supplemental agreement
as provided in 4-3.2.
9-3.4 Deviation from Plan Dimensions: If the Contractor fails to construct
any item to plan or to authorized dimensions within the specified tolerances, the
Engineer, at his discretion will: require the Contractor to reconstruct the work to
acceptable tolerances at no additional cost to the Department; accept the work and
provide the Contractor no pay; or accept the work and provide the Contractor a reduced
final pay quantity or reduced unit price. The Department will not make reductions to final
pay quantities for those items designated to be paid on the basis of original plan quantity
or a lump sum quantity under the provisions of this Article unless such reduction results
in an aggregate monetary change per item of more than $100, except that for earthwark
items, the aggregate change must exceed $5,000 or 5% of the original plan quantity,
whichever is smaller. If, in the opinion of the Engineer, the Contractor has made a
deliberate attempt to take advantage ofthe construction tolerances as defined in 120-12.1
to increase borrow excavation in fill sections or to decrease the required volume of
roadway or lateral ditch excavation or embankment, the Department will take appropriate
measurements and will apply reductions in pay quantities. The Department will not use
the construction tolerance, as defined in 120-12.1, as a pay tolerance. The construction
tolerance is not to be construed as defining a revised authorized template.
9-4 Omitted Entirely (Deleted Work)
9-5 Omitted Entirely (Partial Payments)
9-6 Omitted Entirely (Record of Construction Materials)
9-7 Omitted Entirely (Disputed Amounts Due the Contractor)
9-8 Omitted Entirely (Acceptance and Final Payment)
9-9 Omitted Entirely (Interest Due ou Delayed Payments)
9-10 Omitted Entirely (Offsetting Payments)
9-11 Omitted Entirely (Deleted Work)
9-12 Omitted Entirely (Partial Payments)
9-13 Omitted Entirely (Record of Construction Materials)
9-14 Omitted Entirely (Disputed Amounts Due the Contractor)
9-15 Omitted Entirely (Acceptance and Final Payment)
9-16 Omitted Entirely (Interest Due on Delayed Payments)
9-17 Omitted Entirely (Offsetting Payments)
56
DIVISION II
CONSTRUCTION DETAILS
SECTION 334
SUPERP AVE ASPHALT CONCRETE
334-1 Description.
334-1.1 General: Construct a Superpave Asphalt Concrete pavement with the type of mixture
specified in the Contract, or when offered as alternates, as selected. Superpave mixes are identified as Type
SP-9.5, Type SP-12.5 or Type SP-19.0.
Meet the requirements of Section 320 for plant and equipment. Meet the general
construction requirements of Section 330, including the provision for Quality Control Plans and Quality
Control Systems as specified in 6-8.
The Engineer will accept the work on a LOT-to-LOT basis in accordance with the
applicable requirements of this Specification. The size ofthe LOT will be as specified in 334-5.2.
334-1.2 Traffic Levels: The requirements for Type SP Asphalt Concrete mixtures are based on
the design traffic level of the project, expressed in 18,000 pound Equivalent Single Axle Loads (ESAL's).
The five traffic levels are as shown in Table 334-1.
Table 334-1
Su e ave Traffic Levels
Traffic Level Traffic Level (I x I 0 ESAL's)
A <0.3
B 0.3 to <3
C 3 to <10
D 10 to <30
E >30
The traffic level(s) for the project are as specified in the Contract. A Type SP mix one
traffic level higher than the traffic level specified in the Contract may be substituted, at no cost to the
Department (i.e. Traffic Level B may be substituted for Traffic Level A, etc.).
334-1.3 Gradation Classification: The Superpave mixes are classified as either coarse or fme,
depending on the overall gradation ofthe mixture. Coarse and fine mixes are defmed in 334-3.2.2.
The equivalent AASHTO nominal maximum aggregate size Superpave mixes are as
follows:
Type SP-9.5 ...................................................................................... 9.5 mm
Type SP-12.5 .................................................................................... 12.5 mm
Type SP-19.0 .................................................................................... 19.0 mm
334-1.4 Thickness: The total thickness of the Type SP asphalt layer(s) will be the plan thickness
as shown in the Contract documents. Before paving, propose a thickness for each individual layer meeting
the requirements of this specification, which when combined with other layers (as applicable) will equal the
plan thickness. For construction ptrrposes, the plan thickness and individual layer thickness will be
converted to spread rate based on the maximum specific gravity of the asphalt mix being used, as well as
the minimum density level, as shown in the following equation:
Spread rate (lbs/yd') ~ t x Gmm x 43.3
Where: t ~ Thickness (in.) (Plan thickness or individual layer
thickness)
57
- ~'-
Gmm = Maximum specific gravity from the
verified mix design
The weight of the mixture shall be determined as provided in 320-2.2. For target purposes
only, spread rate calculations should be rounded to the nearest whole number.
Note: Plan quantities are based on a Omm of 2.540, corresponding to a spread rate of
110 Ibs/yd2-in. Pay quantities will be based on the actual maximum specific gravity of the mix being used.
334-1.4.1 Layer Thicknesses - Fine Mixes: The allowable layer thicknesses for fine
Type SP Asphalt Concrete mixtures are as follows:
Type SP-9.5 ............................................................................1 - I 1/2 inches
Type SP-12.5 ....................................................................1 1/2 - 21/2 inches
Type SP-19.0 ................................................................................2 - 3 inches
In addition to the minimum and maximum thickness requirements, the following
restrictions are placed on fine mixes when used as a structural course:
Type SP-9.5 - Limited to the top two structural layers, two layers
.
maximum.
Type SP-9.5 - May not be used on Traffic Level D and E applications.
Type SP-19.0 - May not be used in the fmal (top) structural layer.
334-1.4.2 Layer Thicknesses - Coarse Mixes: The allowable layer thicknesses for
coarse Type SP Asphalt Concrete mixtures are as follows:
Type SP-9.5 ............................................................................1 1/2 - 2 inches
Type SP-12.5 ................................................................................2 - 3 inches
Type SP-19.0 ..........................................................................3 - 31/2 inches
In addition to the minimum and maximum thickness requirements, the following
restrictions are placed on coarse mixes when used as a structural course:
Type SP-19.0 - May not be used in the final (top) structural layer.
334-1.4.3 Additional Requirements: The following requirements also apply to coarse
and fine Type SP Asphalt Concrete mixtures:
1. A minimum I 1/2 inch initial lift is required over an Asphalt Rubber
Membrane Interlayer (ARMI).
7. When construction includes the paving of adjacent shoulders (<5 feet wide),
the layer thickness for the upper pavement layer and shoulder must be the same and paved in a single pass,
unless called for differently in the Contract documents.
3. All overbuild layers must be fine Type SP Asphalt Concrete designed at the
traffic level as stated in the Contract. Use the minimum and maximum layer thicknesses as specified above
unless called for differently in the Contract documents. On variable thickness overbuild layers, the
minimum allowable thickness may be reduced by 1/2 inch, and the maximum allowable thickness may be
increased 1/2 inch, unless called for differently in the Contract documents.
334-2 Materials.
334-2.1 General Requirements: Meet the material requirements specified in Division III.
Specific references are as follows:
Superpave PO Asphalt Binder or Recycling Agent
................... .... ................................. .............. ................... ................ 916-1, 916-2
Coarse Aggregate................................................................................ Section 901
Fine Aggregate.................................................................................... Section 902
334-2.2 Superpave Asphalt Binder: Unless specified otherwise in the Contract, use a PO 67-22
asphalt binder with the following exceptions: for Traffic Level D, use a PO 76-22 asphalt binder in the final
structural layer; for Traffic Level E, use a PO 76-22 asphalt binder in the top two structural layers. In
addition, meet the requirements of334-2.3.
334-2.3 Reclaimed Asphalt Pavement (RAP) Material:
334-2.3.t General requirements: RAP may be used as a component of the asphalt
mixture subject to the following requirements:
58
1. For Traffic Levels A, B and C mixtures, limit the amount of RAP material
used in the mix to a maximum of 50 percent by weight of total aggregate. For Traffic Levels D and E
mixtures, limit the amount of RAP material used in the mix to a maximum of 30 percent by weight of total
aggregate.
2. When using a PG 76-22 Asphalt Binder, limit the amount of RAP material
used in the mix to a maximum of 15 percent by weight of total aggregate.
3. Assume full responsibility for the design, production and construction of
asphalt mixes which incorporate RAP as a component material.
4. Use RAP from an FDOT approved stockpile or RAP that has an FDOT
furnished Pavement Composition Data Sheet.
5. Do not use RAP material in any friction course mixes.
6. Provide stockpiled RAP material that is reasonably consistent in
characteristics and contains no aggregate particles which are soft or conglomerates of fines.
7. Provide RAP material having a minimum average asphalt content of
4.0 percent by weight of tot a! mix. The Engineer may sample the stockpile to verifY that this requirement is
met.
334-2.3.2 Material Characterization: Assume responsibility for establishing the asphalt
binder content, gradation, viscosity and bulk specific gravity (G'b) of the RAP material based on a
representative sampling of the material. Obtain the samples by one of the following methods:
I. Roadway cores: Cut a minimum number of cores to be representative of the
pavement prior to milling. Fill the core holes prior to opening to traffic. Assume responsibility for
accounting for the degradation that will occur during the milling operation.
2. Milling: Obtain representative samples by milling the existing pavement to
the full depth shown on the plans for a minimum length of approximately 200 feet. If required to maintain
traffic, immediately replace the pavement removed with the mix specified in the Contract. This mix will be
paid for at the Contract unit price.
3. Stockpile sampling: Obtain samples from a stockpile of either milled or
processed RAP. Take representative samples at random locations around the stockpile. Request the
Engineer to make a visual inspection of the stockpiled RAP material. Based on visual inspection and a
review of the test data, the Engineer will determine the suitability of the stockpiled materials. Once the
RAP stockpile has been approved, do not add additional material without prior approval of the Engineer.
Determine the binder content and gradation of the RAP material in
accordance with FM 5-563 and FM 1- T 030, respectively. Extract and recover the asphalt binder from the
RAP in accordance with FM 5-524 and FM 3-D 5404, respectively. Determine the viscosity of the
recovered asphalt binder in accordance with ASTM D2171. Establish the G'b of the RAP material by using
one of the following methods:
a) Calculate the G,b value based upon the effective specific
gravity (G,,) of the RAP material, determined on the basis of the asphalt binder content and maximum
specific gravity (G~) of the RAP material. The Engineer will approve the estimated asphalt binder
absorption value used in the calculation.
b) Measure the G'b of the RAP aggregate, in accordance with
FM I-T 084 and FM I-T 085. Obtain the aggregate by using either a solvent or ignition oven extraction
method.
334-2.3.3 Pavement Composition: When the Contract includes milling of the existing
asphalt pavement, the Pavement Composition Data Sheet may be available on the Department's website.
The URL for obtaining this information, if available, is:
http://www.dot.state.fl.us/statematerialsoffice/laboratory/asphaltlcentrallaboratory/compositions/index.htm
334-2.3.4 Asphalt Binder for Mixes with RAP: Select the appropriate asphalt binder
grade based on Table 334-2. The Engineer reserves the right to change the asphalt binder type and grade at
design based on the characteristics of the RAP asphalt binder, and reserves the right to make changes
during production. Maintain the viscosity of the recycled mixture within the range of 4,000 to
12,000 poises. Obtain a sample of the mixture for the Engineer within the tirst 1,000 tons of production and
at a continuing frequency of one sample per 4,000 tons of mix.
59
Table 334-2
As halt Binder Grade for Mixes Containin RAP
Percent RAP Asphalt Binder Grade
<20 PG 67-22
20 - 29 PG 64-22
> 30 Recycling Agent
334-2.4 Recycled Crushed Glass: Recycled crushed glass may be used as a component of the
asphalt mixture subject to the following requirements:
1. Consider the recycled crushed glass a local material and meet all requirements
specified in 902-6.
2. Limit the amount of recycled crushed glass to a maximum of 15 percent by weight of
total aggregate.
3. Use an asphalt binder that contains a minimum of 0.5 percent anti-stripping agent by
weight of binder. The antistrip additive shall be one of the products included on the Qualified Products List
specified in 6-1 of the Specifications. The antistrip additive shall be introduced into the asphalt binder by
the supplier during loading.
4. Do not use recycled crushed glass in friction course mixtures or in structural course
mixtures which are to be used as the fmal wearing surface.
334-3 General Composition of Mixture.
334-3.1 General: Compose the asphalt mixture using a combination of aggregate (coarse, fine or
mixtures thereof), mineral filler, if required, and asphalt binder material. Size, grade and combine the
aggregate fractions to meet the grading and physical properties of the mix design. Aggregates from various
sources may be combined.
334-3.2 Mix Design:
334-3.2.1 General: Design the asphalt mixture in accordance with AASHTO R35-04,
except as noted herein. Prior to the production of any asphalt mixture, submit the proposed mix design with
supporting test data indicating compliance with all mix design criteria to the Engineer. Include
representative samples of all component materials, including asphalt binder. Allow the State Materials
Engineer a maximum of four weeks to either conditionally verifY or reject the mix as designed. Final
verification of the mix design will occur when the requirements of 334-5.2.1 have been met. Do not use
more than three mix designs per nominal maximum aggregate size per traffic level per binder grade per
contract year. Exceeding this limitation will result in a maximum Composite Pay Factor of 1.00 as defmed
in 334-8.2 for all designs used beyond this limit.
The Engineer will consider any marked variations from original test data for a
mix design or any evidence of inadequate field perfonnance of a mix design as sufficient evidence that the
properties of the mix design have changed, and the Engineer will no longer allow the use of the mix design.
334-3.2.2 Mixture Gradation Requirements: Combine the coarse and fme aggregate in
proportions that will produce an asphalt mixture meeting all of the requirements defined in this
specification and conform to the gradation requirements at design as defmed in AASHTO M323-04,
Table 3. Aggregates from various sources may be combined.
334-3.2.2.1 Mixture Gradation Classifieation: Plot the combined mixture
gradation on an FHW A 0.45 Power Gradation Chart. Include the Control Points from AASHTO M323-04,
Table-3, as well as the Primary Control Sieve (PCS) Control Point from AASHTO M323-04, Table 4.
Coarse mixes are defmed as having a combined aggregate gradation that passes below the primary control
sieve control point, and fine mixes are defined as having a gradation that passes above or through the
primary control sieve control point. Use either a coarse mix or fine mix for Traffic Levels A - E.
334-3.2.3 Aggregate Consensus Properties: Meet the following consensus properties at
design for the aggregate blend:
334-3.2.3.t Coarse Aggregate Angularity: When tested in accordance with
ASTM D 5821, meet the percentage of fractured faces requirements specified in AASHTO M323-04,
Table 5.
60
334-3.2.3.2 Fine Aggregate Angularity: When tested in accordance with
AASHTO T-304, Method A, meet the uncompacted void content of fine aggregate specified in
AASHTO M323-04, Table 5.
334-3.2.3.3 Flat and Elongated Particles: When tested in accordance with
ASTM D 4791, (with the exception that the material passing the 3/8 inch sieve and retained on the NO.4
sieve shall be included), meet the requirements specified in AASHTO M323-04, Table 5. Measure the
aggregate using the ratio of5:1, comparing the length (longest dimension) to the thickness (shortest
dimension) of the aggregate particles.
334-3.2.3.4 Sand Equivalent: When tested in accordance with
AASHTO T 176, meet the sand equivalent requirements specified in AASHTO M323-04, Table 5.
334-3.2.4 Gyratory Compaction: Compact the design mixture in accordance with
AASHTO T312-04. Use the number of gyrations as defined in AASHTO R35-04, Table I with the
followin,r exceptions: for Traffic Level C mixes, compact the mixture as specified for the Traffic Level of
0.3 x 10 to < 3 X 106 ESAL's; for Traffic Level E mixes, compact the mixture as specified for 10 x 106 to
< 30 X 106 ESAL's.
334-3.2.5 Design Criteria: Meet the requirements for nominal maximum aggregate size
as defined in AASHTO M323-04, as well as for relative density, VMA, VFA, and dust-to-binder ratio as
specified in AASHTO M323-04, Table 6. Use a dust-to-binder ratio of 0.8 to 1.6 for coarse mixes.
334-3.2.6 Moisture Susceptibility: Test 4 inch specimens in accordance with
FM I-T283. Provide a mixture having a retained tensile strength ratio of at least 0.80 and a minimum
tensile strength (unconditioned) of 100 psi. If necessary, add a liquid anti-stripping agent, which is on the
Department's Qualified Products List or hydrated lime (meeting the requirements of 337-10.2) in order to
meet these criteria.
334-3.2.7 Additional Information: [n addition to the requirements listed above, provide
the following information with each proposed mix design submitted for verificatiou:
I. The design traffic level and the design number of gyrations (Nd"i,.).
2. The source and description of the materials to be used.
3. The DOT source number and the DOT product code of the aggregate
components furnished from a DOT approved source.
4. The gradation and proportions of the raw materials as intended to be
combined in the paving mixture. The gradation of the component materials shall be representative of the
material at the time of use. Compensate for any change in aggregate gradation caused by handling and
.
processmg as necessary.
5. A single percentage ofthe combined mineral aggregate passing each specified
sieve. Degradation of the aggregate due to processing (particularly material passing the No. 200 sieve)
should be accounted for and identified.
6. The bulk specific gravity (G,b) value for each individual aggregate and RAP
component, as identified in the Department's aggregate control program.
7. A single percentage of asphalt binder by weight of total mix intended to be
incorporated in the completed mixture, shown to the nearest 0.1 percent.
8. A target temperature at which the mixture is to be discharged from the plant
and a target roadway temperature (per 330-6.3). Do not exceed a target temperature of 330"F for modified
asphalts and 315"F for unmodified asphalts.
9. Provide the physical properties achieved at four different asphalt binder
contents. One of which shall be at the optimum asphalt content, and must conform to all specified physical
requirements.
10. The name of the CTQP Qualified Mix Designer.
II. The ignition oven calibration factor.
334-3.3 Mix Design Revisions: During production, the Contractor may request a target value
revision to a mix design, subject to meeting the following requirements: (I) the target change falls within
the limits defined in Table 334-3, (2) appropriate data exists demonstrating that the mix complies with
production air voids specification criteria, and (3) the mixture gradation meets the basic gradation
requirements defined in 334-3.2.2.
61
..._~'
Table 334-3
Limits for Potential Adjustments to Mix Design Target Values
Characteristic Limit from Original Mix Design
No.8 sieve and Coarser 0, 5.0 percent
No. 16 sieve 0, 4.0 percent
No. 30 sieve 0, 4.0 percent
No. 50 sieve 0, 3.0 percent
No. 100 sieve + 3.0 percent
No. 200 sieve + 1. 0 percent
Asphalt Binder Content (l) + 0.3 percent
(1) Reductions to the asphalt binder content will not be permitted if the VMA during production is lower than 1.~
ereent below the desi n criteria.
Submit all requests for revisions to mix designs, along with supporting documentation, to
the Engineer. In order to expedite the revision process, the request for revision or discussions on the
possibility of a revision may be made verbally, but must be followed up by a written request. The verified
mix design will remain in effect until the Engineer authorizes a change. In no case will the effective date of
the revision be established earlier than the date of the fIrst communication between the Contractor and the
Engineer regarding the revision.
A new design mix will be required if aggregate sources change, or for any substitution of
an aggregate product with a different aggregate code, unless approved by the Engineer.
334-4 Contractor Process Control.
Assume full responsibility for controlling all operations and processes such that the requirements
of these Specifications are met at all times. Perform any tests necessary at the plant and roadway for
process control purposes. The Engineer will not use these test results in the acceptance payment decision.
Address in the Quality Control Plan how Process Control failures will be handled. Investigate, at a
minimum, the production process, testing equipment and/or sampling methods to determine the cause of
the failure, and make any necessary changes to assure compliance with these Specifications. Obtain a
follow up sample immediately after corrective actions are taken to assess the adequacy of the corrections.
In the event the follow-up Process Control sample also fails to meet Specification requirements, cease
production of the asphalt mixture until the problem is adequately resolved to the satisfaction of the
Engineer.
334-5 Acceptance of the Mixture.
334-5.1 General: The mixture will be accepted at the plant with respect to gradation (P., and P.
200), asphalt content (Pb), and volumetrics (volumetrics is defined as air voids at N',,;gn). The mixture will
be accepted on the roadway with respect to density of roadway cores. Acceptance will be on a LOT-by-
LOT basis (for each mix design) based on tests ofrandom samples obtained within each sublot taken at a
frequency of one set of samples per sublot. A roadway LOT and a plant production LOT shall be the same.
Acceptance of the mixture will be based on Contractor Quality Control test results that have been verified
by the Department.
334-5.1.1 Sampling and Testing Requirements: Obtain the samples in accordance with
FM I-T 168. Obtain samples at the plant ofa sufficient quantity to be split into three smaller samples; one
for Quality Control, one for Verification and one for Resolution testing; each sample at approximately
35 pounds. The split samples for Verification testing and Resolution testing shall be reduced in size and
stored in three boxes each. The approximate size of each box must be 12" x 8" x 4". Label and safely store
these boxes in a manner agreed upon by the Engineer for future testing. The Contractor can retain
additional split samples at their option.
The asphalt content of the mixture will be determined in accordance with
FM 5-563. In the event the FM 5-563 ignition oven goes out of service during production. the Contractor
may elect to use a replacement oven at another location for no more than 72 hours while the oven is being
repaired. The gradation of the recovered aggregate \vill he determined in accordance with FM I-T 030.
62
Volumetric testing will be in accordance with AASHTO T312-04 and FM I-T 209. Prior to testing
volumetric samples, condition the test-sized sample for one hour at the target roadway compaction
temperature in a covered, shallow, flat pan. Test for roadway density in accordance with FM 1- T 166.
334-5.1.2 Acceptance Testing Exceptions: When the total quantity of any mix type in
the Project is less than 500 tons, the Engineer will accept the mix on the basis of visual inspection. The
Engineer may require the Contractor to run process control tests for informational purposes, as defmed in
334-4, or may run independent verification tests to determine the acceptability of the material.
Density testing for acceptance will not be performed on widening strips or
shoulders with a width of 5 feet or less, open-graded friction courses, variable thickness overbuild courses,
leveling courses, first lift of asphalt base course placed on subgrade, miscellaneous asphalt pavement, or
any course with a specified thickness less than I inch or a specified spread rate that converts to less than
I inch as described in 334-1.4. In addition, density testing for acceptance will not be performed on the
following areas when they are less than 1,000 feet in length: crossovers, intersections, turning lanes,
acceleration lanes, deceleration lanes, or ramps. Compact these courses (with the exception of open-graded
friction courses) in accordance with the rolling procedure (equipment and pattern) submitted as part of the
Quality Control Plan and as approved by the Engineer. In the event that the rolling procedure deviates from
the approved procedure, placement ofthe mix shall be stopped.
The density pay factor (as defined in 334-8.2) for LOTs where there are areas
not requiring density testing for acceptance will be prorated based on a pay factor of 1.00 for the quantity
(tonnage) of material in areas not requiring density testing for acceptance and the actual pay factor for the
tonnage of material in areas requiring density.
334-5.2 LOT Sizes: LOT sizes will be either 2,000 tons or 4,000 tons. The Initial Production LOT
of all mix designs used on a project shall consist of 2,000 tons, subdivided into four equal sublots of
500 tons each. Following the Initial Production LOT, each remaining LOT will be defined (as selected by
the Contractor prior to the start of the LOT) as either (I) 2,000 tons, with each LOT subdivided into four
equal sublots of 500 tons each, or (2) 4,000 tons (as authorized by the Engineer per 334-5.2.1), with each
LOT subdivided into four equal sublots of 1,000 tons each. Before the beginning of a LOT, the Engineer
will develop a random sampling plan for each sub lot and direct the Contractor on sample points, based on
tonnage, for each sub lot during construction.
In the event a LOT is terminated per 334-5.4.4, the LOT size upon resuming production
of the mixture will be 2000 tons until the requirements of334-5.2.1 are met.
334-5.2.1 Criteria for 4,000 ton LOTs: At the completion of the Initial Production
LOT, the quality of the as-produced material will be evaluated by the Engineer. Begin the option of
4,000 ton LOT sizes only when authorized by the Engineer based upon the Quality Control test results for
the Initial Production LOT meeting the following:
I. A minimum Pay Factor of 0.90 for each asphalt quality characteristic as
defined in 334-8.2.
2. A favorable comparison with the Verification test results. Comparisons
between the Quality Control and Verification test results will be based on between-laboratory precision
values shown in Table 334-5.
3. A coefficient of permeability of less than 125 x 1O-5cmls on each roadway
core as determined in accordance with FM 5-565. Permeability criteria apply only to coarse mixes when the
average density for the sub lot is less than 93.00 percent of Gnum or when an individual density value is less
than 91.00 percent ofG~.
In the event that the Initial Production LOT does not meet these criteria, limit
production LOT sizes to 2,000 tons with 500 ton sublots until these criteria are met.
334-5.2.2 Partial LOTs: A partial LOT is defined as a LOT size that is less than a full
LOT. A partial LOT may occur due to the following:
1. The completion of a given mix type or mix design on a project.
2. A LOT termination due to a 60 day or greater delay in production.
(Time periods other than 60 days may be used if agreed to by both Engineer and Contractor.)
3. A LOT is terminated per 334-5.4.4.
All partial LOTs will be evaluated based on the number of tests available, and
will not be redefined.
334-5.3 Initial Production Requirements: The Initial Production LOT of all mix designs shall be
established at 2,000 tons. During this period demonstrate the capability to produce and place the mixture as
63
.,.
specified unless waived by the Engineer in 334-3.2.1. If necessary, during this time, make adjustments to
the mix design, as defined in 334-3.3. Any target value adjustments to the mix design will result in the LOT
being terminated and evaluated for payment purposes per 334-8. Do not begin 4,000 ton LOT sizes until a
2,000 ton initial production LOT (for each mix design) has been successfully completed, or is waived by
the Engineer.
At the sole option of the Engineer, the requirement for an Initial Production LOT may be
waived based on evidence of satisfactory production, placement and performance on previous projects for
that particular mix.
334-5.3.1 Plant Sampling and Testing Requirements: Obtain one random sample of
mix per sublot in accordance with 334-5. I.l as directed by the Engineer. Test the Quality Control split
sample for gradation, asphalt binder content and volumetrics in accordance with 334-5.1.1. Complete all
Quality Control testing within one working day from the time the samples were obtained.
334-5.3.2 Roadway Sampling and Testing Reqnirements: Obtain five 6 inch diameter
roadway cores within 24 hours of placement at random locations as directed by the Engineer within each
sublot. Test these Quality Control samples for density in accordance with 334-5.1. I. The O~ used for the
density evaluation will be based on the Quality Control test result for the corresponding sublot.
On coarse mixes when the average density for an Initial Production sublot is less
than 93.00 percent of O~, or an individual core density is less than 91.00 percent of Omm, cut five 6 inch
diameter roadway cores (at locations determined by the Engineer) and have them evaluated for
permeability in accordance with FM 5-565 by a laboratory as approved by the Engineer. If approved by the
Engineer, the original cores cut for density testing purposes may be used to evaluate permeability.
334-5.3.3 Verification of Initial Production LOT: For Verification purposes the
Engineer will test a minimum of one split sample as described in 334-5. I. I from the Initial Production LOT
at the completion of the LOT. Results of the testing and analysis for the LOT will be made available to the
Contractor within one working day from when the LOT is completed.
The Veritication test results will be compared with the corresponding Quality
Control test results based on the between-laboratory precision values shown in Table 334-5.
If all of the specilied mix characteristics compare favorably, then the LOT will
be accepted, with payment based on the Quality Control results for the LOT.
If any of the results do not compare favorably, then the split Resolution samples
from the LOT will be sent to the Resolution laboratory for testing, as described in 334-5.6.
334-5.3.4 Acceptance of Initial Production LOT: The Initial Production LOT shall be
considered a single LOT and will receive a Composite Pay Factor as determined in 334-8, based on results
of the verified Quality Control tests, or as determined by the Resolution System.
334-5.4 Quality Control Sampling and Testing: Obtain all samples randomly as directed by the
Engineer.
Should the Engineer detennine that the Quality Control requirements are not being met or
that unsatisfactory results are being obtained, or should any instances of falsification of test data occur,
approval ofthe Contractor's Quality Control Plan will be suspended and production will be stopped.
334-5.4.1 Lost or Missing Verification/Resolution Samples: In the event that any of
the Verification and/or Resolution samples that are in the custody of the Contractor are lost, damaged,
destroyed, or are otherwise unavailable for testing, the minimum possible pay lactor for each quality
characteristic as described in 334-8.2 will be applied to the entire LOT in question, unless called for
otherwise by the Engineer. Specifically, if the LOT in question has more than two sub lots, the pay factor
for each quality characteristic will be 0.55. If the LOT has two or less sublots, the pay factor for each
quality characteristic will be 0.80. In either event, the material in question will also be evaluated in
accordance with 334-5.9.5.
If any of the Verification and/or Resolution samples that are in the custody of
the Department are lost, damaged, destroyed or are otherwise unavailable for testing, the corresponding
Quality Control test result will be considered verified, and payment will be based upon the Contractor's
data.
334-5.4.2 Plant Sampling and Testing Requirements: Obtain one random sample of
mix per sub lot in accordance with 334-5.1.1 as directed by the Engineer. Test the Quality Control split
sample for gradation, asphalt binder content and volumetrics in accordance with 334-5.1.1. Complete all
Quality Control testing within one working day from the time the samples were obtained.
64
334-5.4.3 Roadway Sampling and Testing Requirements: Obtain five 6 inch diameter
roadway cores within 24 hours of placement at random locations as directed by the Engineer within each
subia!. Test these Quality Control samples for density (Gmb) in accordance with 334-5.1.1. In situations
where it is impractical to cut five cores per sub lot, obtain a minimum of three cores per sublat at random
locations as identified by the Engineer. Do not obtain cores any closer than 12 inches from an unsupported
edge. Maintain traffic during the coring operation; core the roadway, patch the core holes (within three
days of coring); and trim the cores to the proper thickness prior to density testing.
Density for the sublot shall be based on the average value for the cores cut from
the sub lot with the target density being the maximum specific gravity (G~) of the sublo!. Once the average
density of a sublot has been determined, do not retest the samples unless approved by the Engineer. Ensure
proper handling and storage of all cores until the LOT in question has been accepted.
334-5.4.4 Individual Test Tolerances for Qnality Control Testing: In the event that an
individual Quality Control test result of a sub lot for air voids, or the average sub lot density for coarse
graded mixes does not meet the requirements of Table 334-4, terminate the LOT and stop production of the
mixture until the problem is adequately resolved (to the satisfaction of the Engineer), unless it can be
demonstrated to the satisfaction of the Engineer that the problem can immediately be (or already has been)
resolved. Address any material represented by the failing test result in accordance with 334-5.9.5.
In the event that an individual Quality Control test result of a sublot for
gradation (P_, or P.200), asphalt binder content, or the average sub lot density for fine graded mixes does not
meet the requirements of Table 334-4, or an individual core density is less than 91.00 percent of G~ (for
coarse mixes), take steps to correct the situation and report the actions to the Engineer.
In the event that two consecutive individual Quality Control test results (for the
same material characteristic) for gradation (P., and P-200), asphalt binder content, or the average sublot
density for fine graded mixes do not meet the requirements of Table 334-4, or two individual core densities
within a sublot are less than 91.00 percent of G~ (for coarse mixes), terminate the LOT and stop
production of the mixture until the problem is adequately resolved (to the satisfaction of the Engineer),
unless it can be demonstrated to the satisfaction of the Engineer that the problem can immediately be (or
already has been) resolved. Address any material represented by the failing test result in accordance with
334-5.9.5.
Any LOT terminated under this subarticle will be limited to a maximum Pay
Factor of 1.00 (as dermed in 334-8.2) for each quality characteristic.
Table 334-4
Master Production Range
Characteristic Tolerance (I)
A~alt Binder Content ( percent) Ta~UO.55
Passing No.8 Sieve (percent) Tar et Oc5.50
Pass~No. 200 Sieve (nercent) Target Oc 1.50
Air Voids ( ercent) Coarse Graded 2.00 - 6.00
Air Voids nercent) Fine Graded 2.30 - 6.00
Density,nercent Gmm (2)
Coarse Graded (minimum) 93.00
Fine Graded (minimum) 90.00
(1) Tolerances for sample size ofn - 1 from the verified mix design
(2) Based on an avera e of 5 random] located cores
334-5.5 Verification Testing: In order to determine the validity of the Contractor's Quality
Control test results prior to their use in the Acceptance decision, the Engineer will run verification tests.
334-5.5.1 Plant Testing: At the completion of each LOT, the Engineer will test a
minimum of one Verification split sample randomly selected from the LOT. Results of the testing and
analysis for the LOT will be made available to the Contractor within one working day from the time the
LOT is completed. Verification samples shall be reheated at the target roadway compaction temperature for
I 1/2 hours, reduced to the appropriate testing size, and conditioned and tested as described in 334-5.1.1.
The Veriflcation test results will be compared with the Quality Control test
results based on the between-laboratory precision values shown in Table 334-5.
65
---...,.-...._-_..,---~-_.- --,'.-.
Table 334-5
Between-Laborato y Precision Values
Pr~rty Maximum Difference
G~ 0.016
Gmb 0.022
Pb 0.44 percent
P-200 FM 1- T 030 (Figt1re 2)
Ps FM I-T 030 (Figt1re 2)
If all of the specified mix characteristics compare favorably, then the LOT will
be accepted, with payment based on the Contractor's Quality Control test data for the LOT.
If any of the results do not compare favorably, then the Resolution samples from
the LOT will be sent to the Resolution laboratory for testing, as described in 334-5.6.
334-5.5.2 Roadway Testing: At the completion of each LOT, the Engineer will
determine the density (Gmb) of each core (previously tested by Quality Control) as described in 334-5.1.1
from one randomly selected sublot from the LOT. Results of the testing and analysis for the LOT will be
made available to the Contractor within one working day from the time the LOT is completed.
The individual Verification test results will be compared with individual Quality
Control test results by the Engineer based on the between-laboratory precision values given in Table 334-5
for Gmb-
If each of the core test results compare favorably, then the LOT will be accepted
with respect to density, with payment based on the Contractor's Quality Control test data for the LOT.
If any of the results do not compare favorably, then the core samples from the
LOT will be sent to the Resolution laboratory for testing as specified in 334-5.6.
334-5.6 Resolution System:
334-5.6.1 Plant Samples: In the event of an unfavorable comparison between the
Contractor's Quality Control test results and the Engineer's Verification test results on any of the properties
identified in Table 334-5, the Resolution laboratory will test all of the split samples from the LOT for only
the property (or properties) in question. Resolution samples shall be reheated at the target roadway
compaction temperature for 1 1/2 hours, reduced to the appropriate testing size, and conditioned and tested
as described in 334-5.1.1.
334-5.6.2 Roadway Samples: In the event of an unfavorable comparison between the
Contractor's Quality Control test data and the Engineer's Verification test data on the density results, the
Resolution laboratory will test all of the cores from the LOT. Testing will be as described in 334-5.1.1. Any
damaged roadway cores will not be included in the evaluation~ replace damaged cores with additional cores
at the direction of the Engineer.
334-5.6.3 Resolution Determination: If the Resolution laboratory results compare
favorably (for the property or properties in question) with all of the Quality Control results, then acceptance
and payment for the LOT will be based on the Quality Control results, and the Department will bear the
costs associated with Resolution testing. No additional compensation, either monetary or time, will be
made for the impacts of any such testing.
If the Resolution laboratory results do not compare favorably (for the property
or properties in question) with all of the Quality Control results, then acceptance and payment for the LOT
will be based on the Resolution test data for the LOT, and the costs of the Resolution testing will be
deducted from monthly estimates. No additional time will be granted for the impacts of any such testing.
In the event of an unfavorable comparison between the Resolution test results
and Quality Control test results, make the necessary adjustments to assure that future comparisons are
favorable.
334-5.7 Independent Verification Testing:
334-5.7.1 Plant: Take samples as directed by the Engineer for Independent Verification
testing. The Contractor can retain split samples of these samples at their option. Independent Verification
samples will be reheated at the target roadway compaction temperature for I 1/2 hours, reduced to the
appropriate testing size, and conditioned and tested as described in 334-5.1.1. If any of the results do not
meet the requirements of Table 334-4, cease production of the asphalt mixture until the problem is
adequately resolved (to the satisfaction of the Engineer), unless it can be demonstrated to the satisfaction of
66
the Engineer that the problem can immediately be (or already has been) resolved. Address any material
represented by the failing test results in accordance with 334-5.9.5.
334-5.7.2 Roadway: Obtain five roadway cores as directed by the Engineer for
Independent Verification testing. These independent cores will be obtained from the same LOTs and
sublots as the Independent Verification Plant samples, or as directed by the Engineer. The density of these
cores will be obtained as described in 334-5.1.1. If the average of the results for the sublot does not meet
the requirements of Table 334-4 for density, cease production of the asphalt mixture until the problem is
adequately resolved (to the satisfaction of the Engineer), unless it can be demonstrated to the satisfaction of
the Engineer that the problem can immediately be (or already has been) resolved. Address any material
represented by the failing test results in accordance with 334-5.9.5.
334-5.8 Surface Tolerance: The asphalt mixture will be accepted on the roadway with respect to
surface tolerance in accordance with the applicable requirements of330-12.
334-5.9 Minimum Acceptable Quality Levels:
334-5.9.1 Pay Factors Below 0.90: In the event that an individual pay factor for any
quality characteristic of a LOT falls below 0.90, take steps to correct the situation and report the actions to
the Engineer. In the event that the pay factor for the same quality characteristic for two consecutive LOTs
is below 0.90, cease production of the asphalt mixture until the problem is adequately resolved (to the
satisfaction of the Engineer), unless it can be demonstrated to the satisfaction of the Engineer that the
problem can immediately be (or already has been) resolved. Actions taken must be approved by the
Engineer before production reswnes.
334-5.9.2 Composite Pay Factors Less Than 0.90 and Greater Than or Equal to
0.80: If the composite pay factor for the LOT is less than 0.90 and greater than or equal to 0.80, cease
production of the asphalt mixture until the problem is adequately resolved (to the satisfaction of the
Engineer), unless it can be demonstrated to the satisfaction of the Engineer that the problem can
immediately be (or already has been) resolved. Actions taken must be approved by the Engineer before
production resumes.
334-5.9.3 Composite Pay Factors Less Than 0.80 and Greater Than or Equal to
0.75: If the composite pay factor for the LOT is less than 0.80 and greater than or equal to 0.75, address the
defective material in accordance with 334-5.9.5.
334-5.9.4 Composite Pay Factors Less Than 0.75: If the composite pay factor for the
LOT is less than 0.75, remove and replace the defective LOT at no cost to the Department, or as approved
by the Engineer.
334-5.9.5 Defective Material: Assume responsibility for removing and replacing all
defective material placed on the project, at no cost to the Department.
As an exception to the above and upon approval of the Engineer, obtain an
engineering analysis by an independent laboratory (as approved by the Engineer) to determine the
disposition of the material. The engineering analysis must be signed and sealed by a Professional Engineer
licensed in the State of Florida.
The Engineer may determine that an engineering analysis is not necessary or
may perform an engineering analysis to determine the disposition of the material.
Any material that remains in place will be accepted with a composite pay factor
as determined by 334-8, or as determined by the Engineer.
If the defective material is due to a gradation, asphalt binder content or density
failure, upon approval of the Engineer the Contractor may perform delineation tests on roadway cores in
lieu of an engineering analysis to determine the limits of the defective material that requires removal and
replacement. Prior to any delineation testing, all sampling locations shall be approved by the Engineer. All
delineation sampling and testing shall be monitored and verified by the Engineer. The minimum limit of
removal of defective material is fifty-feet either side of the failed sample. For materials that are defective
due to air voids, an engineering analysis is required.
334-6 Comparison Testing.
At the start of the project (unless waived by the Engineer) and at other times as determined
necessary by the Engineer, provide split samples for comparison testing with the Engineer. The purpose of
these tests is to verify that the testing equipment is functioning properly and that the testing procedures are
being performed correctly. In the event that the Engioeer determines that there is a problem with the
Contractor's testing equipment and/or testing procedures, immediately correct the problem to the
67
_,.u......., _.__,_,__.~.
Engineer's satisfaction. In the event that the problem is not immediately corrected, cease production of the
asphalt mixture until the problem is adequately resolved to the satisfaction of the Engineer.
If so agreed to by both the Contractor and the Engineer, the split sample used for comparison
testing may also be used for the Quality Control sample. The split sample used for comparison testing will
also meet the requirements for Independent Verification Testing described in 334-5.7.
334-7 Method of Measurement.
For the work specified under this Section (including the pertinent provisions of Sections 320
and 330), the quantity to be paid for will be the weight of the mixture, in tons.
The bid price for the asphalt mix will include the cost of the liquid asphalt or the asphalt recycling
agent and the tack coat application as directed in 300-8. There will be no separate payment or unit price
adjustment for the asphalt binder material in the asphalt mix. For the calculation of unit price adjustments
of bituminous material, the average asphalt content will be based on the percentage specified in 9-2.1.2.
The weight will be determined as provided in 320-2 (including the provisions for the automatic recordation
system).
Prepare a Certification of Quantities, using the Department's current approved form, for the
certified Superpave asphalt concrete pay item. Submit this certification to the Engineer no later than
Twelve O'clock noon Monday after the estimate cut-off or as directed by the Engineer, based on the
quantity of asphalt produced and accepted on the Contract. The certification must include the Contract
Number, FPID Number, Certification Number, Certification Date, period represented by Certification and
the tons produced for each asphalt pay item.
334-8 Basis of Payment.
334-8.1 General: Price and payment will be full compensation for all the work specified under
this Section (including the applicable requirements of Sections 320 and 330).
Based upon the quality of the material, a pay adjustment will be applied to the bid price
of the material as determined on a LOT by LOT basis. The pay adjustment will be assessed by calculating a
Pay Factor for the following individual quality characteristics: pavement density, air voids, asphalt binder
content, and the percentage passing the No. 200 and No.8 sieves. The pay adjustment will be computed by
multiplying a Composite Pay Factor for the LOT by the bid price per ton. Perform all calculations with the
Department's Asphalt Plant - Pay Factor Worksheets (Form No. 675-030- 12).
334-8.2 Pay Factors:
334-8.2.1 Two or Less Sub lot Test Results: In the event that two or less sublot test
results are available for a LOT, Pay Factors will be determined based on Table 334-6, using the average of
the accumulated deviations from the target value. (Deviations are absolute values with no plus or minus
signs.) Use the I-Test column when there is only one sublot test result and use the 2-Tests column when
there are two sublots.
Table 334-6
Small Quantity Pa Table
Pay Factor T I Sublot Test Deviation 2 Sublot Test A vera e Deviation
Asphalt Binder Content
1.05 0.00-0.23 0.00-0.16
1.00 0.24-0.45 0.17-0.32
0.90 0.46-0.55 0.33-0.39
.--
0.80 >0.55 >0.39
No.8 Sieve
1.05 0.00-2.25 0.00-1.59
~~_._-'..~. -
1.00 2.26-4.50 1.60-3.18
--~'~--'------'--- .-.'.- ,-_., ..-.'-.-----.--- .--...------ .--.------
0.90 4.51-5.50 3.19-3.89
-
0.80 >5.50 >3.89
No. 200 Sieve
1.05 0.00-0.55 0.00-0.39
1.00 0.56-1.10 0.40-0.78
.-
0.90 1.11-1.50 0.79-1.06
-
68
Table 334-6
Small Quantity Pav Table
Pay Factor 1 Sublot Test Deviation 2 Sublot Test A ver~ Deviation
0.80 >1.50 >1.06
Air Voids (Coarse Mixes)
1.05 0.00-0.55 0.00-0.39
1.00 0.56-1.10 0.40-0.78
0.90 1.11-2.00 0.79-1.41
0.80 2.01-2.25 1.42-1.59
0.70 2.26-2.50 1.60-1.77
0.55 >2.50 > 1.77
Air Voids (Fine Mixes)
1.05 0.00-0.50 0.00-0.35
1.00 0.51-1.00 0.36-0.71
0.90 1.01-1.70 0.72-1.20
0.80 1.71-2.00 1.21-1.41
0.70 2.01-2.50 1.42-1.77
0.55 >2.50 >1.77
Densi!l'jCoarse Mixes) Note (1) 0.00-0.35
1.05 0.00-0.50
1.00 0.51-1.00 0.36-0.71
0.95 1.01-1.50 0.72-1.06
0.90 >1.50 >1.06
1.05 Densi!L(Fine Graded Mixtures) Note (1) 0.00-0.35
0.00-0.50
1.00 0.51-1.00 0.36-0.71
0.95 1.01-2.00 0.72-1.41
0.90 2.01-3.00 1.42-2.12
0.80 >3.00 >2.12
ates:
(1) Each density test result is the average of five cores. The target density for coarse mixes is 94.50 percent of Gmm. The
arget density for fine mixes is 93.00 percent of Gmm (92.00 percent when compaction is limited to the static mode a
defined in Note 1 of Table 334-7)
334-8.2.2 Three or More Sublot Test Results: When three or more sublot test results
are available for a LOT, the variability-unknown, standard deviation method will be used to determine the
estimated percentage of the LOT that is within specification limits. The number of significant figures used
in the calculations will be in accordance with requirements of AASHTO R 11-82 (2002), Absolute Method.
334-8.2.2.1 Percent Within Limits: The percent within limits (PWL) and Pay
Factors for the LOT will be calculated as described below. Variables used in the calculations are as
follows:
x
n
s
L(x2)
(Lx)'
Qu
~ individual test value (sublot)
~ number of tests (sublots)
~ sample standard deviation
= summation of squares of individual test values
= summation of individual test values squared
~ upper quality index
USL ~ upper specincation limit (target value plus upper
specification limit from Table 334-7)
QL
~ lower quality index
LSL ~ lower specification limit (target value minus lower
specification limit from Table 334-7)
Pu
PL
~ estimated percentage below the USL
~ estimated percentage above the LSL
69
. -. -...~
(1) Calculate the arithmetic mean (X )ofthe test values:
- 2:>
X=
n
(2) Calculate the sample standard deviation (s):
n I(x')-(Ix)'
n(n -I)
s=
(3) Calculate the upper quality index (Qu):
Qu
USL- X
s
(4) Calculate the lower quality index (Qd:
Q{
X - LSL
s
(5) From Table 334-8, determine the percentage of work below the USL (Pu).
(6) From Table 334-8, determine percentage of work above the LSL (PL) Note:
IfUSL or LSL is not specified; percentages within (lISL or LSL) will be 100.
(7) If Qu or QL is a negative number, then calculate the percent within limits for
Qu or QL as follows: enter Table 334-8 with the positive value of Qu or QL and obtain the corresponding
percent within limits for the proper sample size. Subtract this number from 100.00. The resulting number is
the value to be used in the next step (Step 8) for the calculation of quality level.
(8) Calculate the percent within limits (PWL) ~ (Pu+ Pd - 100
(9) Calculate the Pay Factor (PF) for each quality characteristic usmg the
equation given in 334-8.2.2.2.
Table 334-7
S ecification Limits
Quali Characteristic S ecification Limits
Passin NO.8 sieve ( ercent) Tar et x 3.1
Passin No. 200 sieve ( ercent) Tar et x 1.0
As haIt Content ( ercent) Tar et x 0.40
Air Voids - Coarse Mixes (ercent).___ 4.00 x 1.40
Air Voids - Fine Mixes ( ercent) 4.00 x 1.20
----.----
Density - Coarse Mixes ( ercent of Gmm): 94.50 + 1.30
Density - Fine Mixes ( ercent of Gmm): 93.00 + 2.00, - 1.20 (I)
ote (1): If the Engineer (or Contract Documents) limits compaction to the static mode only, the specification limit
are as follows: 92.00 + 3.00, -1.20. No additional com ensation, cost or time, shall be made.
.. -~-,_.~~-" .-..-
Table 334-8
Percent Within Limits
Quality Index Percent within Limits for Selected Sample Size
n~3 n~4 n~5 n~6
-..'".-.-- ..
0.00 50.00 50.00 50.00 50.00
---- -
70
Table 334-8
Percent Within Limits
Quality Index Percent within Limits for Selected Sam Ie Size
n~3 n~4 n~5 n~6
0.05 51.38 51.67 51.78 51.84
0.10 52.76 53.33 53.56 53.67
0.15 54.15 55.00 55.33 55.50
0.20 55.54 56.67 57.10 57.32
0.25 56.95 58.33 58.87 59.14
0.30 58.37 60.00 - 60.63 60.94
0.35 59.80 61.67 62.38 62.73
0.40 61.26 63.33 64.12 64.51
0.45 62.74 65.00 65.84 66.27
0.50 64.25 66.67 67.56 68.00
0.55 65.80 68.33 69.26 69.72
0.60 67.39 70.00 70.95 71.41
0.65 69.03 71.67 72.61 73.08
0.70 70.73 73.33 74.26 74.71
0.75 72.50 75.00 75.89 76.32
0.80 74.36 76.67 77.49 77.89
0.85 76.33 78.33 79.07 79.43
0.90 78.45 80.00 80.62 80.93
0.95 80.75 81.67 82.14 82.39
1.00 83.33 83.33 83.64 83.80
1.05 86.34 85.00 85.09 85.18
1.10 90.16 86.67 86.52 86.50
1.15 97.13 88.33 87.90 87.78
1.20 100.00 90.00 89.24 89.01
1.25 100.00 91.67 90.54 90.19
1.30 100.00 93.33 91.79 91.31
1.35 100.00 95.00 92.98 92.37
1.40 100.00 96.67 94.12 93.37
1.45 100.00 98.33 95.19 94.32
1.50 100.00 100.00 96.20 95.19
1.55 100.00 100.00 97.13 96.00
1.60 100.00 100.00 97.97 96.75
1.65 100.00 100.00 98.72 97.42
1.70 100.00 100.00 99.34 98.02
1.75 100.00 100.00 99.81 98.55
1.80 100.00 100.00 100.00 98.99
1.85 100.00 100.00 100.00 99.36
1.90 100.00 100.00 100.00 99.65
-
1.95 100.00 100.00 100.00 99.85
.
2.00 100.00 100.00 100.00 99.97
2.05 100.00 100.00 100.00 100.00
2.10 100.00 100.00 -- 100.00 100.00
71
-.".-
"' _.. ~___,.,_".w. _
Table 334-8
Percent Within Limits
Quality Index Percent within Limits for Selected Sample Size
n-3 n-4 n-5 n-6
2.15 100.00 100.00 100.00 100.00
2.20 100.00 100.00 100.00 100.00
2.25 100.00 100.00 100.00 100.00
2.30 100.00 100.00 100.00 100.00
2.35 100.00 100.00 100.00 100.00
2.40 100.00 100.00 100.00 100.00
2.45 100.00 100.00 100.00 100.00
2.50 tOO.OO 100.00 100.00 100.00
2.55 100.00 100.00 100.00 100.00
2.60 100.00 100.00 100.00 100.00
2.65 100.00 100.00 100.00 100.00
following equation:
334-8.2.2.2 Pay Factors (PF): Pay Factors will be calculated by using the
Pay Factor ~ (55 + 0.5 x PWL) / 100
The PWL is determined from Step (8) of334-8.2.2.1.
334-8.3 Composite Pay Factor (CPF): A Composite Pay Factor for the LOT will be calculated
based on the individual Pay Factors (PF) with the following weighting applied: 35 percent Density (D),
25 percent Air Voids (V,), 25 percent asphalt binder content (Ph), 10 percent Passing No. 200 (P.200) and
5 percent Passing No.8 (P.,). Calculate the CPF by using the following formula:
CPF ~ [(0.350 x PF D) + (0.250 x PF V,) ~ (0.250 x PF Ph) +
(0.100 x PF P.200) + (0.050 x PF P.,)]
Where the Pay Factor (PF) for each quality characteristic is determined in either
334-8.2.1 or 334-8.2.2, depending on the number of sublot tests. Note that the number after each
multiplication will be rounded to the nearest 0.01.
The pay adjustment shall be computed by multiplying the Composite Pay Factor for the
LOT by the bid price per ton.
334-8.4 Payment: Payment will be made under:
Item No. 334- 1- Superpave Asphaltic Concrete - per ton.
72
EXHIBIT N
CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT
GC-CA-N-1
Co~er County
~
Adminisb13live Services DMsion
Purchasing
Purchasing Department
3301 Tamiami Trail East
Naples, Florida 34112
Telephone: 239-252.8446
FAX: 239-252-6697
Email: brendabrilhart@collierQov.net ,.",
www.collierQov.net ,,,
c::=>
CSt"
ITEM NO.: 10- PIZL.-(jILf38'DATE RECEIVED:
FILE NO.:
'-
:::t~"
.-r:
I
Cl'
-,~
<.- _...:
.._,-
/' '-
_.~, r--
ROUTED TO:
w
-""
1"-,)
.---1
:J_
~=-
~rT
i::J
""J
DO NOT WRITE ABOVE THIS LINE
From:
st:\
\)~ ~\ <(: \~ ~
Scott Teach JO t/!t>" ~I~
Deputy County Attorney ~~. ~ft V~ ~~ L. l.r l .
Brenda Brilhart, Purchasing Agent ~ 1J.
'\"' ,IV" .
Contract #09-5287 "Oil Well Road Widening - Segments 2 and 4A" ~.er~ ~~J1 (J
Contractor: Mitchell & Stark Construction Co., Inc. 0 L ) g f
v /\
BACKGROUND OF REQUEST: ~.t- )
This contract was approved by the BCC on December 15, 2009; Agenda Item 1 0 ~/
This item has not been previously submitted.
Request for Legal Services
Date:
December 30, 2009
To:
Re:
ACTION REQUESTED:
Contract review and approval.
OTHER COMMENTS:
Please forward to BCC for signature after approval. If there are any questions concerning the document,
please contact me at the telephone number or email address above. Purchasing would appreciate
notification when the documents exit your office. "
W-~~
~ ~\ \ \,0
\:~ ~\.
GI AcquisitionsfT ech FormsandLetters/MemotoRequestLegalServices
Revised: 4/16//09
Co~6r County
~~. .-
AdmInislralJve Services Division
Purchasing
Purchasing Department
3301 Tamiami Trail East
Naples, Florida 34112
Telephone: (239) 252-8446
FAX (239) 252-6697
Email: brendabrilhart@collierqov.net
www.collierqov.net
TO: Jeff Walker/Ray Carter
Risk Management Department
FROM: Brenda Brilhart, Purchasing Agent (}(f/ tk ~~,
Purchasing Department l){Y
DATE: December 30, 2009
RE: Review of Insurance for Contract No. 09-5287 "Oil Well Road
Widening - Segments 2 and 4A"
Contractor: Mitchell & Stark Construction Co., Inc.
This Contract was approved by the BCC on December 15, 2009; Agenda
Item 10 B.
Please review the Bonds and Insurance Certificate in this Agreement for the
above-referenced contract. If everything is acceptable, please forward to
the County Attorney for further review and approval. I would appreciate it if
you would keep me advised on when this document has been forwarded to
the County Attorney's Office.
Thank you and if you have any further questions contact me at the following
telephone number: 252-8446.
'IA1'r
,. ,. RECnVED
? 0 2009
1(1SK ~GEMEN1
C: Gary Putaansuu, Project Manager
GI AcquisitionsfT echFormsandLetters/MemotoRiskforlnsuranceReview
Revised: 4/16/09
mausen 9
From:
Sent:
To:
Cc:
Subject:
RaymondCarter
Wednesday, January 06, 2010 3:03 PM
BrilhartBrenda
mausen_g; putaansuu_g
Contract 09-5287 "Oil Well Road Widening-Segments 2 and 4A"
Alii have approved the certificate of insurance, payment bond and performance bond as provided by Mitchell & Stark
Construction Co., Inc for contract 09-5287. The contract will now be forwarded to the County Attorney's Office for their
review.
Thank you,
Ray
~~
Manager Risk Finanace
Office 239-252-8839
Cell 239-821-9370
Under Florida Law, e-mail addresses are pUblic records. If you do not want your e-mail address released in response to a public records request, do not send
electronic mail to this entity. Instead, contact this office by telephone or in writing.
1
RLS# IO-I'IU.- 1)/1/38
CHECKLIST FOR REVIEWING CONTRACTS
Entity Name: t1-1/7t!H~~'-- rf 5 TrllU< fbA,.!,7d.U"- ""'IV (119.. ltUt!,
.
Insurance
Insurance Certificate attached?
Insured registered in Florida?
Contract # &/or Project referenced on Certificate?
Certificate Holder name correct (BCC)?
Commercial General Liability
General Aggregate Required $ 'Z. ..,-""-~
Products/CompVOp Required $
Personal & Advert Required $
Each Occurrence Required $
Fire/Prop Damage Required $_
Automobile Liability
Bodily Inj & Prop Required $ 2....., L.
Workers Compensation
Each accident Required $ , kt. L.
Disease Aggregate Required $
Disease Each Empl Required $
Umbrella Liability
Each Occurrence Provided $ If) M( L
Aggregate Provided $ ~~"u
Does Umbrella sufficiently cover any underinsured portion?
Professional Liability
Each Occurrence Required $
Per Aggregate Required $ ~
Other Insurance
Each Occur Type:~_~~_~_~__
Entity name correct on contract?
Entity registered with FL Sec. of State')
Required $
County required to be named as additional insured?
County named as additional insured?
Indemnification
Does indemnification meet County standards?
Is County indemnifying other party?
Performance Bond
Bond requirement referenced in contract?
If attached, expiration date of bond
Does dollar amount match contract?
Agent registered in Florida?
Provided $
Provided $
Provided $
Provided $
Provided $
Provided $
.,/ Yes
~Yes
----"",-Yes
--L- Y es
~....c::~Yes
_~Yes
No
No
No
No
No
No
..).M'(..
II
l MtL
'I
3~1 f"
Exp. Date 3(1/,0
Exp. Date ,
'I
Exp. Date lf
Exp. Date to
Exp. Date "
ExpDate .3/1 (,/)
Exp Date 3/11(('
Exp Date~_
Exp Date , '
IMtL
Provided $ I M.(L
Provided $_.~~..._
Provided $ t. I
Provided $
Provided $
11\('(
,
Signature Blocks
Correct executor name in signature block?
Correct title of executor?
Executor authorized to sign for entity?
Proper number of witnesses/notary?
Authorization for executor to sign, if necessary: _,__~
Chairman's signature block?
Clerk's attestation signature block?
County Attorney's signature block?
Attachments
Are all required attachments included?
Exp Date 3/. LIP
Exp Date II
/Yes
No
Exp. Date~_
Exp. Date
Provided $
"/Yes
~Yes
/Yes
Yes
.....L Y es
....v:::: Yes
.__.L~ Y es
~Yes
Yes
./ Yes
V Yes
_,,/ Yes
_~Yes
./Yes
~Yes
Exp Date __
No
No
No
~o
No
No
No
No
........-....No
No
No
No
No
No
No
Reviewer Initials'
Date: I I
04-COA 0 I 0 0/222
www.sunbiz.org - Department of State Page 1 of 2
-
FLORIDA DEPARTMENT OF STATF ~ ",t ,
,. ;.
D I\'ISIO:'\ OF C ORPOR.\llll\S flf/bl2' , " '"
,
- '(\\...l~,""
,..
-"-' ,
Home Contact Us E~Filing Services Document Searches Forms Help
Previous on List Next on List Return To List Entity Name Search
No Events No Name History ~itl
Detail by Entity Name
Foreign Profit Corporation
MITCHELL & STARK CONSTRUCTION CO., INC.
Filing Information
Document Number 845897
FEI/EIN Number 350964820
Date Filed 05/02/1980
State IN
Status ACTIVE
Principal Address
170 W FIRST STREET
MEDORA IN 47260
Changed 01/26/2009
Mailing Address
PO BOX219
MEDORA IN 47260
Changed 02/03/2006
Registered Agent Name & Address
PENNER, BRIAN R
6001 SHIRLEY STREET
NAPLES FL 34109 US
Name Changed: 02/25/2000
Address Changed: 02/25/2000
OfficerlDirector Detail
Name & Address
Title C
MITCHELL, RALPH A
665 SPINNAKER DRIVE
MARCO ISLAND FL 34145
Title PTD
HARRISON, FRED C
6236 WEST CR 50 NORTH
MEDORA IN 47260
Title VSD
PENNER, BRIAN R
6540 HUNTERS ROAD
http://ccfcorp.dos.state.tl.us/scripts/cordet.exe?action=DETFIL&inq_ doc _ num ber=84 5897... 1/7/2010
www.sunbiz.org - Department of State
NAPLES FL 34109
Title VAS
SCAFIDI, DAVID C
2229 SW 50TH STREET
CAPE CORAL FL 33914
Title VAS
NEAL, LEO D
P.O. BOX 368325
BONITA SPRINGS FL 34136
Title VAS
WESTHAFER, MICHAEL P
4510 PINE ROAD
FORT MYERS FL 33908
Annual Reports
Report Year Filed Date
2007 01/08/2007
2008 01/11/2008
2009 01/26/2009
Document Images
01/26/2009 -- ANNUAL REPORT I
01/11/2008 -- ANNUAL REPORT [
01/08/2007 -- ANNUALREPORT [
02/03/2006 n ANNUAL REPORT I
01/10/2005.- ANNUAL REPORT [
02/13/2004 -- ANNUAL REPORT I
02/03/2003 -- ANNUAL REPORT I
02/17/2002 -- ANNUAL REPORT [
02/02/2001 -- ANNUAL REPORT [
02/25/2000" ANNUAL REPorn (
02/21/1999 n ANNUAL REPORT I
02/05/1998 -- ANNUAL REPORT I
02/04/1997 -- ANNUAL REPORT [
06/11/1996 -- ANNUAL REPORT [
02/17/1995 ANNUAL REPORT I
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in PDF format
View image in RDF format
View image in RDF format
View image in RDF format
View image in RDF format
View image in RDF format
View image in RDF format
Page 2 of2
]
I
I
]
I
]
I
]
I
I
I
I
]
1
]
Note: This is not official record. See documents if question or conflictl
~[~y:i~YJ! on Lis!
Ne~t_9ILl-~1
No Events
No Name History
Return To List
Entity Name Search
[S~b;;,itl
I 11(;111(,' I (();',\dl\ LiS I I)(J' LIIndi( :>,,1(C:I(", I rTilill'.: ~;,~IVIi'("; F{):iIlS I liL'Ii) !
Cr'lJr,uilt dr:iJ PII'.ihV F'olici(";
CopYli'Jht 'r 2nD7 S\,.1\,E,' 01 i!(,r,dd, [')r,'I).,lrll1);>111. cf 5',<11('.
http://ccfcorp.dos.state. fl. us/scripts/cordct.exc?action= D ETFIL&in<L doc _ number=845 897...
1/7/2010