The URL can be used to link to this page

CLB Agenda 09/17/2025COLLIER COUNTY Contractors Licensing Board Board of County Commissioners AGENDA Board of County Commission Chambers Collier County Government Center 3299 Tamiami Trail East, 3rd Floor Naples, FL 34112 September 17, 2025 9:00 AM Todd Allen, Chair Kyle E. Lantz, Vice-Chair Stephen M. Jaron Matthew Nolton Robert P. Meister, III Richard E. Joslin, Jr. Jennifer Cassidy Terry Jerulle Kevin Johnson NOTICE: All persons wishing to speak on Agenda items must register prior to presentation of the Agenda item to be addressed. All registered speakers will receive up to three (3) minutes unless the time is adjusted by the chairman. Any person who decides to appeal a decision of this Board will need a record of the proceeding pertaining thereto, and therefore may need to ensure that a verbatim record of the proceedings is made, which record includes the testimony and evidence upon which the appeal is to be based. If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, the provision of certain assistance. Please contact the Collier County Facilities Management Division located at 3335 East Tamiami Trail, Suite 1, Naples, Florida, 34112-5356, (239) 252-8380; assisted listening devices for the hearing impaired are available in the Facilities Management Division. 1. Roll Call 2. Additions or Deletions 3. Approval of Agenda 4. Approval of Minutes 4.A. August 20, 2025 (2025-3576) 5. Public Comments Page 1 of 303 6. Discussion 7. Reports 8. New Business 8.A. Orders of the Board_1 (2025-3592) 8.B. Jean Lefrancois_Infinity Glass & Hardware, LLC_Review of Second Entity. (2025-3577) 9. Old Business 9.A. Daisy Jarery Quezadas Avalos_M & D Professional Plastering of SWFL LLC_Probation Review – Credit. (2025-3487) 9.B. Anthony J. Dimech_R & A Plumbing Contractors Inc_Probation Review – Credit. (2025-3579) 9.C. 2024-15_CEMIS20240004396_ Nova Homes of South Florida Inc. (2025-3581) 9.D. 2025-02_CEMIS20240006352_Sunshine Pools of Naples, LLC. (2025-3582) 10. Public Hearings 10.A. 2025-09_Peter Kallie_Kaltin Construction Inc_CEMIS20250002654. (2025-3584) 10.B. 2025-13_Rene A Aviles_Full Construction Services Inc_CEMIS20250005737. (2025-3583) 10.C. 2025-14_Benjamin Lopez_TopQuality Contractors LLC_CEMIS20250004648. (2025-3585) 11. Next Meeting Date Page 2 of 303 1 COLLIER COUNTY CONTRACTORS LICENSING BOARD August 20, 2025 – 9:00 a.m. Board of County Commission Chambers Collier County Government Center 3299 Tamiami Trail East, 3rd Floor, Naples, FL 34112 Present Members: Todd Allen – Chairman Richard Joslin – Board Member Jennifer Cassidy – Board Member Stephen Jaron – Board Member Matthew Nolton – Board Member Absent Members Terry Jerulle Robert Meister Kevin Johnson Kyle Lantz OTHERS PRESENT Timothy Crotts – Assistant Director, Code Enforcement Fred Clum – Chief Building Official Doug Sposito – Deputy Building Official Michael Bogert – Contractor Licensing Supervisor Ryan Cathey – Operations Supervisor Ronald Tomasko – County Attorney Patrick Neale – Attorney for the board Any person wishing to appeal a decision made by this Board must ensure that a verbatim record of the proceedings is made, which record includes testimony and evidence upon which the appeal is based. 1. Roll Call Chairman Todd Allen called the meeting to order at 9:00 AM. 2. Agenda Additions and Deletions • Item 10A continued for 30 days. Page 3 of 303 2 • Item 10C deleted (case abated). Motion to approve the amended agenda by Richard Joslin; second by Matthew Nolton. Motion carried unanimously. 3. Approval of Minutes (July 16, 2025) Motion to approve by Steven Jaron; second by Richard Joslin. Motion carried unanimously. 4. Public Comment No public comments. 5. Hurricane Preparedness Report Mr. Bogert reminded the Board of Ordinance 22-190, which requires the CLB to reconvene during declared states of emergency in order to authorize issuance of temporary emergency-restricted competency certificates. These certificates may last up to six months and allow qualified contractors from other jurisdictions to assist in recovery. He emphasized the importance of readiness for the 2025 hurricane season. 6. Orders of the Board Motion by Chairman Allen to authorize signing of Board orders; seconded and approved unanimously. 7. Old Business 7A. NOVA Homes South Florida, Inc. (Qualifier: Mrs. Dacosta) • Background: Previous Board orders (October 16, 2024 and December 18, 2024) required completion of a project and issuance of a Certificate of Occupancy. The orders warned that failure to comply would revoke permit-pulling privileges across Collier County. Page 4 of 303 3 • Staff Report (Mr. Crotts): Staff recommended privileges not be reinstated, citing continued failure to obtain a Certificate of Occupancy despite time extensions and a private settlement with the homeowners (the Gatos). • Attorney Kerry Goggin (for NOVA Homes): Asserted that a confidential settlement transferred the permit to the homeowners as Owner-Builder, resolving disputes. He argued no further cure was possible and compliance should be considered achieved through the settlement. • Deputy Building Official Doug Sposito: Testified multiple deficiencies remained unresolved. Some simple issues were corrected (truss repair, window compliance), but four major structural concerns persisted. Submitted affidavits were inadequate; engineering reports were rejected. X-ray testing revealed rebar discrepancies (No. 8 required, No. 5 found). No destructive testing had been provided to verify compliance. • Board Concerns: Members expressed that the settlement effectively attempted to “negotiate away” compliance obligations. They emphasized the Board’s duty to protect the public by ensuring projects are completed properly. • Discussion of Remedies: The Board weighed permanent revocation versus suspension. Attorney Neal advised suspension with review periods may be more appropriate than indefinite revocation. Several members stressed accountability and the need for concrete verification. • Motion: Continue case for 30 days, leaving revocation in place, pending further engineering reports from the homeowner’s engineer. Additionally, Board attorneys may be granted in-camera review of the settlement agreement if permitted by parties. • Vote: Motion passed unanimously. 7B. Juan Carlos Lopez – License Review • Background: At July meeting, Mr. Lopez was ordered to provide proof of a credit score of 660 or greater. • Staff Report: Mr. Lopez submitted a credit report showing a score of 621 (previously 591). Staff acknowledged improvement but noted the threshold had not yet been met. • Recommendation: Reinstate license with six-month probation, requiring Mr. Lopez to raise his score to 660 or greater. If achieved, probation will be lifted; if not, he must return before the Board. • Motion: Motion by Chairman Allen to reinstate license with six-month probation; second by Richard Joslin. • Vote: Motion passed unanimously. Page 5 of 303 4 8. Public Hearings 8A. Case of Peter Kallie (Kaltin Construction – Permit Violation) • Respondent’s Request: Mr. Kallie, requested a continuance, stating new counsel (Mr. Justin Gistle) had only been retained the day prior and additional documents (15 pages) were introduced late. He emphasized his limited prior appearances and the complexity of hurricane-related allowances. • Staff Report: Staff opposed continuance, noting Mr. Kallie had known of the charges since June and no timely communication had been received from counsel. • Board Discussion: Members debated fairness to the displaced homeowner versus Mr. Kallie’s right to representation. Some expressed frustration at repeated delays; others stressed due process. • Motion: Motion by Steven Jaron to grant a final continuance of 30 days, with case to be heard at the next scheduled meeting without further delay regardless of attorney availability. • Vote: Motion passed 4–1. 9. Next Meeting The next CLB meeting is scheduled for September 17, 2025. 10. Adjournment There being no further business, the meeting adjourned at 11:20 AM. COLLIER COUNTY CONTRACTORS’ LICENSING BOARD _________________________________________ Chairman Todd Allen The Minutes were approved by ____________________________________ Chairman Todd Allen as presented___________________ Page 6 of 303 5 or amended____________________ Page 7 of 303 CONTRACTORS’ LICENSING BOARD COLLIER COUNTY, FLORIDA ORDER TO PAY CIVIL PENALTY Jose Mendiola 137 Wanatah Ave Lehigh Acres, FL 33974 CLB Agenda Date: 9/17/2025 Pursuant to Section 489.127,Florida Statutes,Operations and Regulatory Management Department/Licensing Section issued Citation No.12225 CEUL20250008325 on 07/11/25,to Jose Mendiola,in the amount of $1,000.00,within 10 days of issuance of the Citation,THE PENALTY HAS NOT BEEN PAID.Per Section 489.127(5)(g),Florida Statutes,the violator is hereby ORDERED to pay that penalty in full within 15 days from the date of mailing a copy of the ORDER to the violator’s address as noted on the Citation.If the penalty is not paid in full within 15*days,this ORDER may be recorded in the public records of Collier County and thereafter shall constitute a lien against any real or personal property owned by the violator.After 3 months from the filing of any such lien which remains unpaid,the Contractor Licensing Board may authorize the County Attorney to foreclose on the lien. ___________________________________DATE: ______________ CHAIRMAN _____ Todd Allen _____ Print Name __________________________________________________________ Attorney to the CLB PATRICK NEALE Code Enforcement Supervisor Michael Bogert For Contractor Licensing Board * If the 15th day falls on a Saturday, Sunday or holiday, the entire fine must be paid no later than 4:00 P.M. on the County’s next business day following that weekend or holiday. Approved as to form and legal sufficiency Page 8 of 303 Page 9 of 303 Page 10 of 303 Page 11 of 303 Page 12 of 303 Page 13 of 303 Page 14 of 303 Page 15 of 303 Page 16 of 303 Page 17 of 303 Page 18 of 303 Page 19 of 303 Page 20 of 303 Page 21 of 303 Page 22 of 303 Page 23 of 303 Page 24 of 303 Page 25 of 303 Page 26 of 303 Page 27 of 303 Page 28 of 303 Page 29 of 303 Page 30 of 303 Page 31 of 303 Page 32 of 303 Page 33 of 303 Page 34 of 303 Page 35 of 303 Page 36 of 303 Page 37 of 303 Page 38 of 303 Page 39 of 303 Page 40 of 303 Page 41 of 303 Page 42 of 303 Page 43 of 303 Page 44 of 303 Page 45 of 303 Page 46 of 303 Page 47 of 303 Page 48 of 303 Page 49 of 303 Page 50 of 303 Page 51 of 303 Page 52 of 303 Page 53 of 303 Page 54 of 303 Page 55 of 303 Page 56 of 303 Page 57 of 303 1 Findings of Fact, Conclusions of Law and Decision of the Board Collier County Contractor Licensing Board For Applications Submitted to the Board for Review Type of Application: X Credit Report Review Waiver of Testing Requirements Reinstatement of License Request to Qualify Second Entity Other (specify) THIS CAUSE came on for public hearing before the Contractor Licensing Board (hereafter Board) on August 21, 2024, for consideration of an application submitted to the Board for review. The application submitted is for a license as a Plaster and Stucco Contractor. Daisy Jarery Quezadas Avalos, dba M&D Professional Plastering of SWFL, LLC (hereinafter “Applicant”) is before the Board for review of her credit score and a determination of whether the Applicant’s credit should prevent the license from being issued to the Applicant. The Board, having heard testimony under oath, received other evidence, and heard arguments relative to all appropriate matters thereupon, issues its Findings of Fact, Conclusions of Law and Order of the Board as follows: FINDINGS OF FACT 1. The Applicant applied to the Collier County Contractor Licensing Supervisor, or his designee, for issuance of a license as a Plaster and Stucco Contractor. 2. Based on the credit report supplied by the Applicant to the Licensing Supervisor, a review of the creditworthiness of the Applicant by the Board is necessary. 3. The Applicant was present at the public hearing and was not represented by counsel. Page 58 of 303 2 4. The Applicant has demonstrated to the Board’s satisfaction that the Applicant has improved her creditworthiness to be issued the subject license subject to certain restrictions. CONCLUSIONS OF LAW 1. All notices required by the Code of Laws and Ordinances of Collier County, as amended, have been properly issued and the Board has jurisdiction over the matter. 2. Pursuant to Section 22-184(b) of the Code of Laws and Ordinances of Collier County, as amended, the subject application met the requirement(s) requiring Board review and approval of the application. 3. The Applicant has sufficiently demonstrated to the Board that she meets the creditworthiness standard(s) as set out in Code of Laws and Ordinances of Collier County, as amended, to be issued a license as a Plaster and Stucco Contractor subject to certain restrictions. ORDER OF THE BOARD 1. Based upon the foregoing Findings of Fact and Conclusions of Law, and pursuant to the authority granted as applicable in Chapter 489, Florida Statutes, and Code of Laws and Ordinances of Collier County, as amended, by a vote of 6 in favor and 0 opposed, a unanimous vote of the Board present, the application for licensure as a Plaster and Stucco Contractor is hereby granted. 2. The subject license is placed on a probationary term for up to twelve (12) months. If at any time the credit report is 660 or greater the probationary period shall be lifted. If the score has not improved to at least 660 at the conclusion of the probationary term the Page 59 of 303 Applicant shall appear back before this Board to explain the reason(s) the score is below the 660 minimum requirement. ORDERED by the Contractor Licensing Board effective the 21st day of August, 2024. CONT R LICEN IN COLL NTY, M. Jaron,hairman I HEREBY CERTIFY that a true and correct copy of the above and foregoing Findings of Fact, Conclusions of Law, and Order of the Board has been furnished to the Applicant, and Timothy Crotts, Contractor Licensing Supervisor, 2800 North Horseshoe Drive, Naples, FL 34103 on this 14r,,day of *,>,r.'*r, 20 2''/ Secretary/Contractor Licensing Board G BOARD IDA By 3 Page 60 of 303 aEP4,1:15PM t&perion Credit scores FICO@ Score 8 Experian Prepared ForDAISYQ,AVALOS Dat gcn.rat d: Junl,2024 Your score is below the average score of U'S' consumers, though many lenders will approve loans with this score. d-.bb 4.'^ dJf .'% 584 t 850300 FE:iC..--rliLt> Experianr**, What's helping @ Long credit history What's hurting - Negative items . You have an established credit history. . Your oldest account was opened: 'l 2 Years, 'l 1 Months ago o FICO High Achievers opened their oHlst account 25 years agq on average. . Average age of your accounts: 4 Years, 1 0 Months . Most FICO High Achievers have an average age of accounts of 9 years or more- r FICO@ Scores measure tte age of the oldest account and the average age of all accounts beifig reported. Generslly speaklng, havlng a relatlvely long credit history and not opening many new accounts is reflective of lower rislc o You have a serious delinquency or derogatory indicator, publlc record and/or collection on your credlt report. o Number of your accounts that were ever 60 deys late or wors€ or have s derogatory indicator 1 2 accounts . Virtually no FlCo High Achievas have a 60 days late paymefit or worse listed on their credit ,eport. . Nurnber of collections on your credit report; I cofiection . VirtualV no FICO High Achievers have a public record..or colle.c.tion listed on their credit report o The presence of a serious dellnquency or derogatory indicator and a derogatory puHlc record (suctr as a bankruptcy) or collection is a powerful predictor of firture payment rist( How€ver, newer yersions of the score including FIGO@ Score 9, FICOO Score 1 0, and FICOO Score 'l 0 T only consider unpald collections. Most collections. publlc remrds and delinquencles stay on the report for no more than seven yeare - though thare are certsln ltem6 that could remain longer. As these items agg they may have less impact on the FlcO@ Score. Satisf ing the Frblic record or paying off the collectlon will not remove the item from a credit report. And it will still be considered by a FICOO Sco.e as long a9 it ls reponed. - High credit usage o You've made heavy use of your avallable revolvlng credlt. . Ratio of your revolving balances to your eredit limits: 99% Page 61 of 303 613f24,'t:15PM t&Oeriqn. Experian Prepared For DAISY Q. AVALOS Drt gcnrr.t d: Jun 3, 2024 Public records No public records reported, Page 62 of 303 6t3124:'l:15 PM !.&perion lnquiries 70OCR/RICK HE},IDRICK CH lnquired on Jul14 2022 Business Typs Automobile Dealers, Us€d 5665 AIRPORT RD N NAPLES, FL 34109 (239) s91-0991 This inquiry is scheduled to continue on re6o.d umilAug 2024 AME( lnquired on Apr 26, 2024 Business Typ€! Bank Credit Cards 2OO VESEYST NEW YORK NY 10285 (800\ 874-2717 This inquiry is scheduled to continue on record untll May 2026 CAP ONE NA lnquired on Jul 12,2022 Business Type: Bank Credit Cards PO BOX 30281 SALT LAKE CTTY, UT 841 30 (8n0) 227-482s This inquiry is scheduledto eontinue on record until Aug 2024 CITI CARDSCENA lnquired on Nov 20, 2023 Eusiness Type: Bank Credit Cards PO BOX 6000 SIOUX FALLS, SD 57117 (800) 950-s114 Experian AMEX lnquired on Aug I 7, 2023 Business Type: Eaok Credit Cards 2OO VESEY ST NEW YORK NY 10285 (8Og) 87+2717 This inquiryis sdleduled to contlnu€ on record until Sep 2025 CAPTALONEAUTO FITT lnquired on Jul 14,2022 Business Typs Auto Fioancing Companies PO BoX 259407 PLANO, TX 75025 (800) 94ffi332 This inquiry is sclteduled to €-ontinue on recod until Aug 2024 CITI CARDS CBNA lnquired on Msy 1 9, 2022 Business Type: Bank eredit Cards PO BOX 6000 stoux FALLS, SD 5-l1 17 (800) 9s&5114 Prepared For DAISY q. AVAIoS Oatc ganarrtadr Jun 3,2024 ALLY FINANCIAL lnquired on Jul 14 2022 Eusiness Typei Auto Financing Companies 2OO RENAISSANCE CTR. DETROII MI 48243 (24e1263-3004 This ingulry is scheduled to continue on recorduntil Aug 2024 GAP ONE NA Inquired on Nov 20, 2023 Business Type: Bank Credlt Cards PO BOX 30281 SALT LAKE CITY, UT 84130 (800't227.4F25 This inquiry ts scieduled to conllnue on record until Oec 2025 CITI CARDS CBNA lnquired on Mar 15, 2024 Eusin€ss Type: Bank Cr€dit Cards PO BoX 6000 stoux FALLS, sD 571 1 7 (800) 950.5114 This inquiry ls scheduled to continue on record untilApr 2026 COMENTTYCAP]TAUBURUN lnquired on Jufl 9, 2022 Business Type: G€nerul Clothing Store P0 80x 182 i20 COLUMBUS, OH 432,18 ALLY FINANCIAL lnqulred on Jul 14,2022 Business Type Auto Flnancing Companies 3OI O W AGUA FRIA FWY STE PHOEN|X, AZ 85027 (866\ 462-2770 This inquiry is scheduled to conllnue on record until Aug 2024 Page 63 of 303 613124, li15PM Experian ?&perion. Disclaimer Prepared ForDAlsYq. AVAIOS D.t gsn r.t di Jun 3,2024 About your FICO@ Score I or other FICO@ Scores Your FICO@ Score 8 powered by Experian data is formulated using the information in your credit file at the tlme it is requested, Many but not all lenders use FlcO@ Score 8. ln addition tothe FlCo@ Score 8,we may offer and provide other base or indusiry-specific FICOo Scores (such as FICO@ Auto Scores and FlcO@ Bankcard scores). The other FICO0 Scores made available are calculat€d from versions ofthebase and industry-specifi c Flco@ Score models. Base FtCO@ Scores (including the FICO@ Score 8) rangefrom 3O0to 850. lnduslry€pecific FICO@ Scores range from 250-900. Hlgher scores represent a greater likelihood ihat youllpay back your debts so yog are viewed as belng a lower credit lisk to lenders. A lower FICOo Score indicates to lenders that you may be a higher credlt rlsk. There are many scoring models used in the marketplace. The type of score used, and its associated risk levels, may vary ftom lender to lender. But regardless ot what scoring model ls used, th€y all have one purpose: to summarize your creditworthiness. Keep in mind that your score is jusl one factor used in the application process, Other factors, such as your annualsalary and lengfr of employment, may also be considered by lenders whfi you applyfor a loan. What this means to you: Credit scor,ng can help you understand your overall credit rating and help companies betler understand how to serYe you. Overallbenefits of credit scoring have included faster credit approvals, redustion in human effor and bias, consistency, and bette. terms end retes for Amerlcan consumers through reduced costs and losses for lenders. Yourlender or insurer mayuse a dilfere Flcoo Scorethan FlCo@ Score I or other base or industry-specific Flco@ Scores provided by us, or different scoring models to determine how you scote. Page 64 of 303 613124.1i15PM Expeian For FICO High Achiev€rs, the average ratio of the revolvtng account balances to credit limtts ls lese than 7%- The Flcoo Score evaluates b6lances ln relatloh lo avei,able cr€dit on revolvlng accoLrnts- The extsnt ot 6 personc cr6dlt usage ls orc of tho mogt important faclors considered by a FICO@ Score. People who keep lheir ralio of balances to credit limits lower are generally consid€red less risky to lenderc than those whh higher ralios. Note. consolidating or moving debt kom one Bccnunt to anoth€r wlll usu€lly not change $e rol6l amouht owed. Bad payment history . You have one or more acaounts showing missed paymenls or derogalory indicslors . Nufiber of your accounts with a missed paym€nt ot derogato,r/ indicatoc '14 accounts . About 98% of Flco High Achievers have no mlssed payments at all. But of those who dq the missed paymmt happdned nesrly 4 years ago, ofl aver6ge. . The presence of missed and late paymehts or d€rogatory Indicators on a credit report including the humber of lst pEyrnenls, how late tiey were and lT ow recently they occuned, are correlated riyith future credit d6k. Your FlCo(E Score w66 lo$/ered due to the number of miss€d and late paymenta and/or accounts with derogatory indicators reported. as the number of sccounts wlth delinquency or derogatory lndicatorg d€cresses. they hev€ less lmpact on a FICO@ Score. - Recent collection and/or PR . You have a rcceflt public r€cod and/or collection on yow credit eport Your most rccent mll€cllon occufi€d: 7 Months sgo Vlrtually no FICO High Achieve6 have a public record or collectlon listed on $eir credit report The recency of 6 detogatory public record (such as a bankruprcy) or collecllon ls a powerful pr€dlctor of hfJr? p.yment rlsk. Howover, newer verslors of the score includit'|g FICOO Score 9, FICO1a Score 10, afld FICoO Scors l0 T only consider unpsld collectio[s. Note, s.tisfying th6 public recod or poying otf the coll€cdoh wlll not remove the lt€m ahd lt will still be consldered by o FICO@ Scorc as long is i( ls reporl€d. As ftese hems sgq th€y may hEve less impact on a FICO@ Saare. Most publia rccoads and collections stay on your report foa no more tian s6v€n years.lhough lhere are certaln items that could r€rnsin longer Page 65 of 303 Findings of Fact, Conclusions of Law and Decision of the Board Collier County Gontractor Licensing Board For Applications Submitted to the Board for Review Type of Application: X Credit Report Review Waiver of Testing Requirements Reinstatement of License Request to Qualify Second Entity Other (specify) THIS CAUSE came on for public hearing before the Contractor Licensing Board (hereafter Board) on August 21, 2024, for consideration of an application submitted to the Board for review. The application submitted is for a specialty license of Plumbing Contractor. Anthony J. Dimech, dba R&A Plumbing Contractors INC (hereinafter "Applicant") is before the Board for review of his credit score and a determination of whether the Applicant's credit should prevent the license from being issued to the Applicant. The Board, having heard testimony under oath, received other evidence, and heard arguments relative to all appropriate matters thereupon, issues its Findings of Fact, Conclusions of Law and Order of the Board as follows: FINDINGS OF FACT 1. The Applicant applied to the Collier County Contractor Licensing Supervisor, or his designee, for issuance of a specialty license of Plumbing Contractor. 2. Based on the credit report supplied by the Applicant to the Licensing Supervisor, a review of the creditworth iness of the Applicant by the Board is necessary. 3. The Applicant was present at the public hearing and was not represented by counsel. I Page 66 of 303 4. The Applicant has demonstrated to the Board's satisfaction that the Applicant has improved his creditworthiness to be issued the subject license subject to certain restrictions. CONCLUSIONS OF LAW 1. All notices required bythe CodeofLawsand Ordinances of Collier County, as amended, have been properly issued and the Board has jurisdiction over the matter. 2. Pursuant to Section 22-1 84(b) of the Code of Laws and Ordinances of Collier County, as amended, the subject application met the requirement(s) requiring Board review and approval of the application. 3. The Applicant has sufficiently demonstrated to the Board that he meets the creditworthiness standard(s) as set out in Code of Laws and Ordinances of Collier County, as amended, to be issued a specialty license of Plumbing Contractor subject to certain restrictions. ORDER OF THE BOARD 1. Based upon the foregoing Findings of Fact and Conclusions of Law, and pursuant to the authority granted as applicable in Chapter 489, Florida Statutes, and Code of Laws and Ordinances of Collier County, as amended, by a vote of 6 in favor and 0 opposed, a unanimous vote of the Board present, the application for a specialty license of Plumbing Contractor is hereby granted. 2. The subject license is placed on a probationary term for up to twelve (12) months. lf the credit report is 660 or greater the probationary period shall be automatically lifted. lf the score has not improved to at least 660 at the twelve (12) month period, the Applicant 2 Page 67 of 303 shall appear back before this Board to explain the reason(s) the score is below the 660 minimum requirement. ORDERED by the Contractor Licensing Board effective the 2'lst day of August, 2024. CONT OR LICEN NG BOARD RIDACOLRUNTY, F B v:Steph n M. Jaron,hairman I HEREBY CERTIFY that a true and correct copy of the above and foregoing Findings of Fact, Conclusions of Law, and Order of the Board has been furnished to the Applicant, and Timothy Crotts, Contractor Licensing Supervisor,2800 North Horseshoe Drive, Naples, FL 34103 on this / 3r, Secretary/Contractor Licensing Board 3 day of .SeYr.naaz 2029 . Page 68 of 303 7l'18124,11:49 AM Your Credit Health I Credit Karma o View report from Ju[ 18, 2024 ANTHONY DIMECH 628 Ca[cutated using Vantagescore 3.0 Provided by Equifax Persona[ lnformation H4l For You Credit https JArvww- cre d itka rma. com/cred it-health/equifax/credrt+eporup rint IE EU6 Cards Loans Money 1ta,Page 69 of 303 CONTRACTORS' LICENSING BOARD COLLIER COUNTY, FLORIDA BOARD OF COUNry COMMISSIONERS COLLIER COUNTY, FLORIDA Petitioner, Case No: CEM1520240004396 License No. 28576 ) ) ) ) ) ) ) ) ) ) ) ) ) ) MAHARAI DACOSTA, NOVA HOMES OF SOUTH FLORIDA INC Respondent ORDER THIS CAUSE came on for public hearing before the Contractors' Licensing Board (hereafter Board) on August 20, 2025, for consideration of the Administratlve Complaint filed against MAHARAI DACOSTA, qualifier of record for NOVA HOMES OF SOUTH FLORIDA lNC, hereinafter the "Respondent". The Board having at said hearing heard testimony under oath, received evidence, and heard arguments respective to all appropriate matters, thereupon issues its Findings of Fact, Conclusions of Law, and Order of the Board as follows: Page 1 of 7 4275291 1t1412016 Page 70 of 303 FINDINGS OF FACT '1 . That Respondent is licensed as a STATE CERTIFIED GENERAL Contractor, AND COLLIER COUNry LICENSED GENERAL CONTRACTOR and the qualifier of record for NOVA HOMES OF SOUTH FLORIDA INC. 2. That the Board of County Commissioners of Collier County, Florida, is the complainant in this matter 3. That the Board has jurisdiction over the Respondent and the Respondent was present with attorney Cary Goggln at the public hearing. 4. Service of the Complaint and all notices required by the Code of Laws and Ordinances of Collier County, Florida, have been properly issued in accordance with Section 22-201 of the Code of Laws and Ordinances of Collier County, Florida. 6. The Respondent presented testimony and evidence to support a Continuance of this hearing to permit further review of the inspection reports from the professional hired by the homeowner regarding the construction of the dwelling in question. 8. The Board also considered testimony regarding a setflement agreement between the Respondent and the homeowner. Page 2 of 7 4275291 111412016 5. The hearing was properly opened by the Board. 7. The evidence and testimony presented by the Respondent and the petitioner support a Continuance to permit completion of the inspections. Page 71 of 303 9. The Board also suggests that counsel for the Respondent and the homeowner permit counsel for the Board to review the settlement agreement between the parties rn camera in order to provide a summary of the settlement agreement, not revealing any confidential material contained in the settlement agreement, to the Board. 1 0. The hearing was not closed by the Board CONCLUSIONS OF LAW 1. Collier County has jurisdiction over this matter and the Respondent 2. The settlement agreement does not impact the Board's jurisdiction over this matter as to misconduct by a licensed contractor. ORDER OF THE BOARD Based on the foregoing Findings of Fact and Conclusions of Law and pursuant to the authority granted in Chapter 489, Florida Statutes, and the Code of Laws and Ordinances of Collier County, Florida, by a vote of 5 in favor and 0 opposed, a unanimous vote of the Board members present and voting, the Board orders this hearing to be Continued to the September 2025 Contractor Licensing hearing for further consideration of the issues presented. The Respondent, any other party, the chairman of the Conhactors' Licensing Board, the contractors' Licensing Board as a body, or the assistant county attorney who tried the case may request a rehearing of any decision of the contractors' Licensing Board. A request for rehearing shall be in writing and shall be filed with staff and a copy Page 3 of 7 427529.1 1114/2016 Page 72 of 303 thereof should be delivered to all other parties within twenty (20) days from the date of mailing or other method of delivery to the Respondent(s) of the Board's written decision. A request for rehearing must be based only on the ground that the decision was contrary to the evidence or that the hearing involved an error on a ruling of law that was fundamental to the decision of the Board. The written request for rehearing must specify the precise reasons therefore. The decision of the Board that is the subject of the rehearing request will remain in effect throughout the rehearing procedure unless the Board orders otheruise. The Board will make a determination as to whether or not to rehear the matter and its decision shall be made at a public meeting, which will be reduced to writing and mailed to the interested parties within 21 days afterthe determination is made. lf the Contractors' Licensing Board determines it will grant a rehearing, it may: a. Schedule a hearing where the parties will be given the opportunity of presenting evidence or argument limited by the Board to the specific reasons for which the rehearing was granted; or b. Modify or reverse its prior decision, without receiving further evidence, providing that the change is based on a finding that the prior decision of the Board resulted from a ruling on a question of law that the Board had been informed by its counsel was an erroneous ruling and which ruling could affect the substantive decision. The parties are further notified that upon the timely filing of a Notice of Appeal within thirty (30) days you may have the decision of the Board reviewed pursuant to the Page 4 of 7 427529.1 1t1412016 Page 73 of 303 procedure set out herein. The Respondent may appeal a decision of the Board to the Collier County Circuit Court. Such an appeal shall not be a hearing de novo but shall be limited to appellate review of the record created before the Board. Any appeal shall be filed with the Circuit Court and served on the parties within thirty (30) days of the mailing of the decision of the Board under the Code of Laws and Ordinances of Collier County, Florida, Section 22-202(d(9).lf there has been a re-hearing request granted, the appeal shall be filed with the Circuit Court and served on the parties within thirty (30) days of the mailing of the re-hearing decision under Code of Laws and Ordinances of Collier County, Florida, Section 22-205. ln the event that the Respondent elects to appeal, a verbatim record and transcript of the proceedings will be necessary. lt shall be the sole responsibility of said party to ensure that a record is made from which a transcript may be prepared which includes the testimony upon which an appeal may be taken. Neither Collier County nor the Board has any responsibility to provide a verbatim record transcript of the proceedings. ln accordance with Section 489.131 (7) (c) and (d), Florida Statutes, the disciplined contractor, the complainant, or the Department of Business and Professional Regulation may challenge the Board's recommended penalty to the State Construction lndustry Licensing Board. Such challenge must be filed within sixty (60) days of the issuance of the recommended penalty to the State Construction lndustry Licensing Board in Tallahassee, Florida. lf challenged, there is a presumptive finding of probable cause and the case may proceed before the state Board without the need for a probable cause hearing. Page 5 of 7 427529.1 1t1412016 Page 74 of 303 Failure of the disciplined contractor, the complainant, or the Department of Business and Professional Regulation to challenge the Board's recommended penalty within the time period set forth herein will constitute a waiver of the right to a hearing before the State Construction lndustry Licensing Board and be deemed as an admission of the violation such that the penalty recommended will become a final order according to the procedures developed by State Board rule without further State Board action. Pursuant to Section 120.59, Florida Statutes, the parties are hereby notified that they may thereafter appeal the Final Order of the State Board by filing one copy of a Notice of Appeal with the Clerk of the Department of Business and Professional Regulation, Northwood Centre, 1940 Monroe Street, Tallahassee, Florida 32399-0792, and by filing the filing fee and one copy of the Notice of Appeal with the appropriate District Court of Appeal within thirty (30) days of the effective date of said State Board Order. ORDERED by the Contractors' Licensing Board effective the 2 of August, 2025 Allen hair ontractors' Licensing Board Page 6 of 7 4275291 1t1412a16 Page 75 of 303 I HEREBY CERTIFY that a true and correct copy of the above and foregoing Findings of Fact, Conclusions of Law, and Order of the Board has been furnished to the Respondent; and Tim Crotts, Licensing Compliance Supervisor, 2800 North Horseshoe Drive, Naples, FL 34103,on this 7C day of /h^q"r<? ,--d-2025. M?T= Secretary / Contractors' Licensing Board Page 7 of7 427529.1 1t14t2016 Page 76 of 303 1 COLLIER COUNTY CONTRACTORS LICENSING BOARD August 20, 2025 – 9:00 a.m. Board of County Commission Chambers Collier County Government Center 3299 Tamiami Trail East, 3rd Floor, Naples, FL 34112 Present Members: Todd Allen – Chairman Richard Joslin – Board Member Jennifer Cassidy – Board Member Stephen Jaron – Board Member Matthew Nolton – Board Member Absent Members Terry Jerulle Robert Meister Kevin Johnson Kyle Lantz OTHERS PRESENT Timothy Crotts – Assistant Director, Code Enforcement Fred Clum – Chief Building Official Doug Sposito – Deputy Building Official Michael Bogert – Contractor Licensing Supervisor Ryan Cathey – Operations Supervisor Ronald Tomasko – County Attorney Patrick Neale – Attorney for the board Any person wishing to appeal a decision made by this Board must ensure that a verbatim record of the proceedings is made, which record includes testimony and evidence upon which the appeal is based. 1. Roll Call Chairman Todd Allen called the meeting to order at 9:00 AM. 2. Agenda Additions and Deletions • Item 10A continued for 30 days. Page 77 of 303 2 • Item 10C deleted (case abated). Motion to approve the amended agenda by Richard Joslin; second by Matthew Nolton. Motion carried unanimously. 3. Approval of Minutes (July 16, 2025) Motion to approve by Steven Jaron; second by Richard Joslin. Motion carried unanimously. 4. Public Comment No public comments. 5. Hurricane Preparedness Report Mr. Bogert reminded the Board of Ordinance 22-190, which requires the CLB to reconvene during declared states of emergency in order to authorize issuance of temporary emergency-restricted competency certificates. These certificates may last up to six months and allow qualified contractors from other jurisdictions to assist in recovery. He emphasized the importance of readiness for the 2025 hurricane season. 6. Orders of the Board Motion by Chairman Allen to authorize signing of Board orders; seconded and approved unanimously. 7. Old Business 7A. NOVA Homes South Florida, Inc. (Qualifier: Mrs. Dacosta) • Background: Previous Board orders (October 16, 2024 and December 18, 2024) required completion of a project and issuance of a Certificate of Occupancy. The orders warned that failure to comply would revoke permit-pulling privileges across Collier County. Page 78 of 303 3 • Staff Report (Mr. Crotts): Staff recommended privileges not be reinstated, citing continued failure to obtain a Certificate of Occupancy despite time extensions and a private settlement with the homeowners (the Gatos). • Attorney Kerry Goggin (for NOVA Homes): Asserted that a confidential settlement transferred the permit to the homeowners as Owner-Builder, resolving disputes. He argued no further cure was possible and compliance should be considered achieved through the settlement. • Deputy Building Official Doug Sposito: Testified multiple deficiencies remained unresolved. Some simple issues were corrected (truss repair, window compliance), but four major structural concerns persisted. Submitted affidavits were inadequate; engineering reports were rejected. X-ray testing revealed rebar discrepancies (No. 8 required, No. 5 found). No destructive testing had been provided to verify compliance. • Board Concerns: Members expressed that the settlement effectively attempted to “negotiate away” compliance obligations. They emphasized the Board’s duty to protect the public by ensuring projects are completed properly. • Discussion of Remedies: The Board weighed permanent revocation versus suspension. Attorney Neal advised suspension with review periods may be more appropriate than indefinite revocation. Several members stressed accountability and the need for concrete verification. • Motion: Continue case for 30 days, leaving revocation in place, pending further engineering reports from the homeowner’s engineer. Additionally, Board attorneys may be granted in-camera review of the settlement agreement if permitted by parties. • Vote: Motion passed unanimously. 7B. Juan Carlos Lopez – License Review • Background: At July meeting, Mr. Lopez was ordered to provide proof of a credit score of 660 or greater. • Staff Report: Mr. Lopez submitted a credit report showing a score of 621 (previously 591). Staff acknowledged improvement but noted the threshold had not yet been met. • Recommendation: Reinstate license with six-month probation, requiring Mr. Lopez to raise his score to 660 or greater. If achieved, probation will be lifted; if not, he must return before the Board. • Motion: Motion by Chairman Allen to reinstate license with six-month probation; second by Richard Joslin. • Vote: Motion passed unanimously. Page 79 of 303 Page 1 of 7 427529.1 1/14/2016 CONTRACTORS’ LICENSING BOARD COLLIER COUNTY, FLORIDA ___________________________________ ) BOARD OF COUNTY COMMISSIONERS ) COLLIER COUNTY, FLORIDA ) ) Petitioner, ) ) vs. ) Case No: 2025‐02 CEMIS20240006352 License No. LCC20230002495 ) LAURIE ROMAS, ) SUNSHINE POOLS OF NAPLES, LLC ) ) ) Respondent ) ___________________________________ ) ORDER THIS CAUSE came on for public hearing before the Contractors' Licensing Board (hereafter Board) on March 19, 2025, for consideration of the Administrative Complaint filed against LAURIE ROMAS, qualifier of record for SUNSHINE POOLS OF NAPLES, LLC, hereinafter the “Respondent”. The Board having at said hearing heard testimony under oath, received evidence, and heard arguments respective to all appropriate matters, thereupon issues its Findings of Fact, Conclusions of Law, and Order of the Board as follows: FINDINGS OF FACT 1. That Respondent is licensed as a SWIMMING POOL/SPA MAINTENANCE AND REPAIR Contractor and the qualifier of record for SUNSHINE POOLS OF NAPLES, LLC Page 80 of 303 Page 2 of 7 427529.1 1/14/2016 2. That the Board of County Commissioners of Collier County, Florida, is the complainant in this matter. 3. That the Board has jurisdiction over the Respondent, the Respondent was present at the public hearing, and Respondent was not represented by counsel. 4. Service of the Complaint and all notices required by the Code of Laws and Ordinances of Collier County, Florida, have been properly issued in accordance with Section 22-201 of the Code of Laws and Ordinances of Collier County, Florida. 5. The evidence presented, testimony given, and on the admission of guilt stated by the Respondent as to Count I, established that the Respondent acted in a manner that is in violation of the Code of Laws and Ordinances of Collier County, Florida, as follows: a. Count I - Respondent, lMS. LAURIE ROMAS failed her obligation, as a contractor, and has caused, a willful building code violation for a FAILED (708) Electrical Final Inspection. 6. That the Contractors' Licensing Supervisor and County staff presented sworn testimony, and the administrative complaint and exhibits thereto were admitted into evidence. The Respondent was afforded an opportunity to present sworn testimony, exhibits, and to cross-examine the Contractors’ Licensing Supervisor and witnesses. The Board was afforded an opportunity to ask questions of the witnesses. Page 81 of 303 Page 3 of 7 427529.1 1/14/2016 7. The allegations of fact as set forth in the Administrative Complaint are true and therefore such facts are hereby found to be supported by competent, substantial evidence presented at the hearing. CONCLUSIONS OF LAW 1. The facts as alleged and set forth in the Administrative Complaint as to Count I were supported by competent and substantial evidence and this evidence provided clear and convincing proof that the Respondent committed the one violation as set forth in the Administrative Complaint. 2. The Respondent violated Code of Laws and Ordinances of Collier County, Florida, Sec 22- 201 in the performance of Respondent’s contracting business in Collier County by acting in willful violation of the sections set out with particularity in the Administrative Compliant. 3. Collier County has jurisdiction over this matter and the Respondent. ORDER OF THE BOARD Based on the foregoing Findings of Fact and Conclusions of Law and pursuant to the authority granted in Chapter 489, Florida Statutes, and the Code of Laws and Ordinances of Collier County, Florida, by a vote of 6 in favor and 0 opposed, a unanimous vote of the Board members present and voting, the Board finds Respondent guilty of misconduct by a holder of a Collier County Certificate of Competency to wit as to Count I, Respondent, MS. LAURIE ROMAS, failed her obligation, as a contractor, and has caused, a willful building code violation for a FAILED (708) Electrical Final Inspection. Page 82 of 303 Page 4 of 7 427529.1 1/14/2016 Upon motion made and seconded and consideration of the following factors; 1. Gravity of the violation, 2. Impact of the violation, 3. Any actions taken by the violator to correct the violation, 4. Any previous violations committed by the violator, 5. Any other evidence presented at the hearing by the parties relevant as to the sanction that is appropriate for the case given the nature of the offense, by a vote of 6 in favor and 0 opposed, a unanimous vote of the Board members present and voting, the Board hereby imposes the following disciplinary sanction(s) upon the Respondent: 1. As to Count 1, the Respondent’s permit pulling privileges in Collier County, City of Naples, and City of Marco Island are revoked. The Respondent, any other party, the chairman of the Contractors’ Licensing Board, the Contractors’ Licensing Board as a body, or the assistant county attorney who tried the case may request a rehearing of any decision of the Contractors’ Licensing Board. A request for rehearing shall be in writing and shall be filed with staff and a copy thereof should be delivered to all other parties within twenty (20) days from the date of mailing or other method of delivery to the Respondent(s) of the Board's written decision. A request for rehearing must be based only on the grounds that the decision was contrary to the evidence or that the hearing involved an error on a ruling of law that was fundamental to the decision of the Board. The written request for rehearing must specify the precise reasons, therefore. The decision of the Board that is the subject of the rehearing request will remain in effect throughout the rehearing procedure unless the Board orders otherwise. Page 83 of 303 Page 5 of 7 427529.1 1/14/2016 The Board will make a determination as to whether or not to rehear the matter and its decision shall be made at a public meeting, which will be reduced to writing and mailed to the interested parties within 21 days after the determination is made. If the Contractors' Licensing Board determines it will grant a rehearing, it may: a. Schedule a hearing where the parties will be given the opportunity of presenting evidence or argument limited by the Board to the specific reasons for which the rehearing was granted; or b. Modify or reverse its prior decision, without receiving further evidence, providing that the change is based on a finding that the prior decision of the Board resulted from a ruling on a question of law that the Board had been informed by its counsel was an erroneous ruling and which ruling could affect the substantive decision. The parties are further notified that upon the timely filing of a Notice of Appeal within thirty (30) days you may have the decision of the Board reviewed pursuant to the procedure set out herein. The Respondent may appeal a decision of the Board to the Collier County Circuit Court. Such an appeal shall not be a hearing de novo but shall be limited to appellate review of the record created before the Board. Any appeal shall be filed with the Circuit Court and served on the parties within thirty (30) days of the mailing of the decision of the Board under the Code of Laws and Ordinances of Collier County, Florida, Section 22-202(g)(9). If there has been a re-hearing request granted, the appeal shall be filed with the Circuit Court and served on the parties within thirty (30) days of the mailing of the re-hearing decision under Code of Laws and Ordinances of Collier County, Florida, Section 22-205. Page 84 of 303 Page 6 of 7 427529.1 1/14/2016 In the event that the Respondent elects to appeal, a verbatim record and transcript of the proceedings will be necessary. It shall be the sole responsibility of said party to ensure that a record is made from which a transcript may be prepared which includes the testimony upon which an appeal may be taken. Neither Collier County nor the Board has any responsibility to provide a verbatim record transcript of the proceedings. In accordance with Section 489.131(7) (c) and (d), Florida Statutes, the disciplined contractor, the complainant, or the Department of Business and Professional Regulation may challenge the Board’s recommended penalty to the State Construction Industry Licensing Board. Such challenge must be filed within sixty (60) days of the issuance of the recommended penalty to the State Construction Industry Licensing Board in Tallahassee, Florida. If challenged, there is a presumptive finding of probable cause and the case may proceed before the State Board without the need for a probable cause hearing. Failure of the disciplined contractor, the complainant, or the Department of Business and Professional Regulation to challenge the Board’s recommended penalty within the time period set forth herein will constitute a waiver of the right to a hearing before the State Construction Industry Licensing Board and be deemed as an admission of the violation such that the penalty recommended will become a final order according to the procedures developed by State Board rule without further State Board action. Pursuant to Section 120.59, Florida Statutes, the parties are hereby notified that they may thereafter appeal the Final Order of the State Board by filing one copy of a Notice of Appeal with the Clerk of the Department of Business and Professional Page 85 of 303 Regulation, Northwood Centre, 1940 lVlonroe Street, Tallahassee, Florida 32399-0792, and by filing the filing fee and one copy of the Notice of Appealwith the appropriate District Court of Appeal within thirty (30) days of the effective date of said State Board Order. ORDERED by the Contractors' Licensing Board effective 9th day of March 2025 Todd Allen, Chair Contractors' Licensing Board I HEREBY CERTIFY that a true and correct copy of the above and foregoing Findings of Fact, Conclusions of Law, and Order of the Board has been furnished to the Respondent; and Tim Crotts, Licensing Compliance Supervisor, 2800 North Horseshoe Drive, Naples, FL34103, on tnis tb dayof ,*grit ,2025. Secretary / Contractors' Licensing Board Page 7 of7 427529.1 1t14t2016 Page 86 of 303 1 COLLIER COUNTY CONTRACTORS LICENSING BOARD Mar. 19, 2025 – 9:00 a.m. Board of County Commission Chambers Collier County Government Center 3299 Tamiami Trail East, 3rd Floor, Naples, FL 34112 Todd Allen, Chairman Kyle E. Lantz, Vice Chair Stephen M. Jaron (excused) Terry Jerulle Matthew Nolton Robert P. Meister, III (excused) Richard E. Joslin, Jr. (excused) Jennifer Cassidy Kevin Johnson OTHERS PRESENT Patrick Neale, Attorney for Contractors Licensing Board Ryan Cathey, Code Enforcement Derek Perry, Attorney for Collier County Timothy Crotts, Assistant Division Director, Code Enforcement Division of CLB Michael Bogert, Collier County Contracting Licensing Supervisor Greg St. Jean, Collier County Licensing Investigator Timothy Broughton, Licensing Agent, Collier County Fred Clum, Chief Building Official, Collier County Any person who decides to appeal a decision of the Contractors Licensing Board will need a record of the proceedings pertaining thereto, and therefore may need to ensure that a verbatim record of the proceedings is made, which record includes the testimony and evidence upon which the appeal is to be based, Neither Collier County nor the Contractors Licensing Board shall be responsible for providing this record. 1. ROLL CALL Michael Bogert, Collier County Code Enforcement, Div. of Contractor Licensing 2. ADDITIONS OR DELETIONS Michael Bogert 3. APPROVAL OF AGENDA Terry Jerulle motioned to approve the Agenda with above changes Matthew Nolton seconded Motion passed 6-0 4. APPROVAL OF MINUTES A. Feb. 19, 2025 Kyle Lantz made the motion to approve the Minutes Page 87 of 303 9 Roman Raab Answered yes to all of the above questions Chairman Allen The count is a violation of County Code of Law Ordinances section 22 dash 2 0 1 sub paragraph two, which states in pertinent part that it is misconduct by a holder of the State Florida license to willfully violate the applicable building code or laws of the State, City or call your County. Do we have any motions as to determination of guilt or innocence? Matthew Nolton I'll make a motion that we find guilty of a lawful violation of the Florida Terry Jerulle seconded Keven Johnson abstained himself from voting because this matter came up on another Board he sat on. Motion passed 5-0 Terry Jerulle motioned to close the public hearing Kyle Lantz seconded Motion passed 6-0 Chairman Allen • Upon consideration of all testimony received under oath, evidence received an argument presented by the parties during the public hearing. The board issues the following findings and conclusions. One service of the administrative complaint and notice was sufficiently provided and in compliance with the applicable law, the respondent is the holder of a license set forth in administrative complaint. The respondent was present at the hearing and was represented by counsel. The board has jurisdiction over the respondent and subject matter race. • In the administrative complaint, the respondent committed the violations as set forth in count one of the administrative complaint, therefore, by a vote of five in favor, zero opposed, and one abstained. And the respondent is found guilty of the violation set forth in count one of the complaint and the administrative complaint. And the board imposes the following sanctions against the respondent. The county is to submit the complaint and order from today's hearing to the Florida Department of Business and Professional Regulation. A. 2025-02 Laurie Romas, Sunshine Pools of Naples, LLC. PRSPL20220942199 Chairman Allen motioned to open the public hearing Matthew Nolton seconded Motion passed 6-0 Timothy Broughton, Licensing Agent, Collier County • I will read an opening statement. The respondent, Laurie Romus, the State certified swimming pool contractor with license number CPC 1 4 6 0 2 9 4 is the qualifier for Sunshine Pools of Naples LLC, Sunshine Pools of Naples LLC has contracted for and receive payment from the property owner for the installation of a swimming pool and screen enclosure at 5 5 3 3 Wilmer Lane, Naples, Florida on September 30th, 2024. • I made telephone contact with the owner of Sunshine Pools of Naples LLC Mr. Christopher Romus. I advised him of the complaint and failed 7 0 8 pool electrical final inspection and Mr. Romus was given a timetable to correct the issue On December 10th, 2024. A review of county records revealed the 7 0 8 pool electrical final inspection for permit number Paul Robert Sam Page 88 of 303 10 Paul Lincoln 2 0 2 2 0 9 4 2 1 9 9 remain failed with no attempts to correct since October 2nd, 2024. • Mr. Romus is in violation of Collier County Code of Laws and Ordinances. Section 22 dash 2 0 1 0.12, which dates impertinent part that willfully violating the applicable building codes or laws of the state, city or Collier County shall constitute misconduct and grounds for discipline. • I want to make note the Contractor was scheduled to appear in the February licensing board asked for a continuance, it was granted. And I did see, receive email confirmation from the qualifier herself on 2 18 25 confirming the 3 19, 20 25 at nine A.M. contractor licensing board hearing. Mr. London Lecca The homeowner testified that he had contracted with Sunshine Pools, to build a pool and screen enclosure. Payment was made on the contract. Chairman Allen made a motion of finding of guilt that they willfully violated the, the laws of Collier County with regard to the permit or the inspection. Terry Jerulle seconded Motion passed 6-0 Chairman Allen motioned to close the public hearing Matthew Nolton seconded Motion passed 6-0 Chairman Allen • Hearing none in opposition and upon consideration of all testimony received under oath, evidence received and arguments presented by the parties during the public hearing, the board issues the following findings and conclusions. Service of the administrative complaint notice was sufficiently provided and in compliance with the applicable law, the respond respondent is the holder of the license as set forth in the administrative complaint. The respondent was not present at the hearing. • The Board has jurisdiction over the respondent. Subject matter raised in the administrative complaint, the respondent committed the violations set, set as set forth in count one of the administrative complaint. Therefore, by a vote of six in favor and zero opposed, the respondent is found guilty of the violations as set forth in count one of the complaint. In count one of the administrative complaint in the board imposes the following sanctions against the respondent. The respondent's permit pooling privileges will be revoked. This concludes the order of the bat order of the board on this matter. 11. NEXT MEETING DATE Wednesday, Apr. 16, 2025 Collier County Government Center Third Floor 12. MEETING ADJOURNED Chairman Allen motioned to adjourn There being no further business for the good of The County, the Contractors’ Licensing Board meeting was adjourned at 11:45 a.m. Page 89 of 303 BEFORE THE COLLIER COUNTY CONTRACTORS' LICENSING BOARD BOARD OF COUNTY COMMISSIONERS, COLLIER COUNTY, FLORIDA, Petitioner, V. MR. PETER KALLIE OBA KAL TIN CONSTRUCTION INC Respondent. Case No: 2025-09 Licensee No: LCC20200000737 CEMIS20250002654 I ADMINISTRATIVE COMPLAINT Collier County (County) files the Administrative Complaint against PETER KALLIE, (Respondent), a Collier County licensed contractor with license number 202000000488, and states the following facts and allegations in support of the cited violations below: 1. The Respondent is currently licensed as a REGISTERED GENERAL CONTRACTOR by Collier County Contractors' Licensing (RG291103895). 2. The Respondent, PETER J KALLIE, is the Collier County license holder of record for KAL TIN CONSTRUCTION, LLC, (Q23167). 3. Under the provisions of Chapter 489 Florida Statutes [§489.105(12) F.S.] and the Code of Laws and Ordinances of Collier County, Florida [Sec. 22-202], the Collier County Contractors' Licensing Board (Board), is authorized to impose penalties against Collier County Certificate of Competency holders who violate the Code of Laws and Ordinances of Collier County, Florida. 4. Under the provisions of the Code of Laws and Ordinances of Collier County, Florida Sec 22-202, the following actions of the Respondent constitute misconduct and grounds for discipline. 5. On March 7th, 2025, the Collier County Contractor Licensing Department received a public portal complaint from Yanela Macias, property owner, for an expired permit, and commencing work prior to an issued permit at 5334 Treetops DR, Naples. FL. Contractors' Licensing case # CEMIS20250002654 was opened to investigate the complaint. Page 90 of 303 6. Upon investigation, it was discovered in March 2023, Associa Gulf Coast Property Management entered into a contract with Kaltin Construction Inc to remove and repair subfloor rot from water damage for $15,000 at 5334 Treetops Dr., Naples, FL. 7. On July 16, 2024, Scott Ctvrtnik, Site Plans Reviewer II (Fire) placed a CO Hold on permit# PRMFH20230416452 for unpermitted demo work in 5334 Treetops Dr. 8. On February 6, 2025, Scott Ctvrtnik, Site Plans Reviewer II (Fire), met with Mr. Kallie at 5334 Treetops Dr and identified work commenced outside the scope of permit # PRMFH20230416452. Mr. Ctvrtnik notes to Mr. Kallie were: His work shall require a revision to be submitted by the contractor, signed and sealed by a design professional, including all additional work performed, electrical intent and electrical pages for work performed, and electrical contractor added to the Permit. 9. On March 7, 2025, a review of County records revealed permit PRMFH20230416452 had been applied for on April 19, 2023, and issued June 6, 2023, with subsequent issued and rejected revisions. 10.On April 25, 2025, the last revision to permit# PRMFH20230416452 was rejected with no new permit progress. 11. On June 24th, 2025, a Notice of Hearing to appear before the Collier County Contractors' Licensing Board on July 16th, 2025, at 9:00 a.m. was served by United States Postal Service certified mail to the Respondent, PETER J KALLIE. A Phone call to PETER KALLIE on July 7, 2025, confirmed he was aware of the hearing time, date and place. 12. Based on the investigation, and pursuant to the Code of Laws and Ordinances of Collier County, Florida Section 22-201 (2), the Contractors' Licensing Supervisor determined sufficient cause exists to warrant the filing of formal charges. 13. The County now brings the following count(s) in this Administrative Complaint against the Respondent: COUNT I A. Upon review of County permitting records, a building permit was never applied for or issued prior to commencing work, and a permit was required to perform the subject scope of work. B. PETER J KALLIE is in violation of Collier County Code of Laws and Ordinances Section 22-201 (18), which states, in pertinent part, that it is misconduct by a holder of a Collier County Certificate of Competency, to proceed on any job without Page 91 of 303 obtaining applicable permits or inspections from the City building and zoning division or the County building review and permitting department. WHEREFORE, the Petitioner asserts the above facts and charges are grounds for disciplinary action under the Code of Laws and Ordinances of Collier County, Florida Sec. 22-201 and WHEREFORE, in consideration of the foregoing, the Petitioner respectfully requests the Collier County Contractors' Licensing Board to find the Respondent guilty of the violation(s) charged. Dated: 7 -7 .,.,. 7-S: Michael Bog Contractors' Licensing Supervisor Page 92 of 303 Contractors' Licensing Board 2800 North Horseshoe Dr. Naples, FL 34104 Complaint Case Number: 2025-9 Complainant: Any person who believes that a Contractor holding a State Certification or Certificate of competency has violated Collier County Ordinance 90-105, as amended, may submit a sworn complaint to the Contractor Licensing supervisor, or his/her designee. The complaint shall be in substantially the form prescribed by the Contractor Licensing Supervisor. The complaining party shall state with particularity which section(s) of this Ordinance he or she believes has been violated by the contractor and the essential facts in support thereof. Complaint: Please print or type and return signed copies of the complaint. Date: July 1, 2025 Against: Contractor's Name: Peter J Kallie Phone: (239) 253-3181 Business Name: KAL TIN CONSTRUCTION LLC. License(s) Held: Registered General Contractor Collier County Issuance #(s): 202000000488 Contractor's Business Address: 18247 Royal Hammock BLVD, Naples, FL 34114 Filed By: Name: Anthony D Simmonds Address: 2800 N. Horseshoe Dr., Naples, FL 34104 Business Phone: 239-631-9615 Address where work is done: 5334 Treetops DR City: Naples County: Collier Page 93 of 303 Date of contract: N/ A Date job started: 19 th March 2023 Date job completed or new home occupied: NIA Were there plans and specifications? Yes Is there a written contract? Yes If yes, amount of Contract:$ NIA Has the Contractor been paid in full? N/ A If not, what amount? NI A Was a Building Permit obtained? Yes Was a Building Permit required? Yes Building Permit number if known: PRMFH20230416452 Have you communicated by letter with the licensee? Yes Date: 11 th June 2025 Do you have a reply? Yes Please attach to this form all copies of the purchase agreement, building contract, home improvement contract, copies of receipts and/or cancelled checks available and any additional evidence to substantiate your allegations. List any subsections of Collier County Ordinance number 22-201, which, in your opinion, have been violated by the contractor, which is the subject of this complaint, (list subsection number): a. Collier County Ordinance 22-201(18) Proceeding on any job without obtaining applicable permits or inspections from the city building and zoning division or the county building review and permitting department. Please state the facts which you believe substantiate your charge of misconduct against the subject contractor. List facts separately for each subsection number above: a. Collier County Ordinance 22-201(18) Proceeding on any job without obtaining applicable permits or inspections from the city building and zoning division or the county building review and permitting department. 1. Upon review of County permitting records, a building permit was never applied for or issued prior to commencing work, and a permit was required to perform the subject scope of work. Page 94 of 303 Anthony Simmonds Code Enforcement Investigator-Licensing State of flo t'Zil)Jtl County of 8 C,/4,lr3' €? The foregoing instrument was acknowledged before me by means of~physical presence or D online notarization on this .ld_ day of ~J l( , 20 ;s-, by Such person(s) Notary Public must check applicable box: ~e personally known to me □ has produced a current driver license □ has produced _____________ as identification. (Notary Seal) Notary Signature: ~vd;t.., HELEN BUCHILLON Commission# HH 651619 Expires May 15, 2029 Page 95 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net Date: July 14, 2025 Peter Kallie Kaltin Construction Inc. 18247 Royal Hammock Blvd. Naples, FL 34114 RE: Case # CEMIS20250002654 – 5334 Treetops Dr. F2 Date of Violation: March 7, 2025 Violation: Commencing work prior to an issued permit (FBC 105.1); Failure to act following County staff's directive to address the rejected revisions. Dear Sir/Madam, A complaint has been filed against you by the above referenced entity. A hearing of this complaint will be held by the Contractors’ Licensing Board on Wednesday August 20, 2025, at 9:00 AM in the Board of County Commissioner’s Room, Third Floor, Administration Building (W. Harmon Turner Bldg.), at 3301 East Tamiami Trail, Naples, Florida 34112. Your presence before the Collier County Contractors’ Licensing Board is required at this time. The packet concerning your case marked composite exhibit “A” will be delivered to the members of the Contractors’ Licensing Board one week prior to the hearing. If you wish to receive a copy of this packet, please notify the Contractor Licensing Customer Service Office. If you wish to prepare a defense packet and have it delivered in conjunction with composite exhibit “A”, you must make fifteen copies and have them in our office by 8:00 AM on Wednesday, one week prior to the hearing. In your packet, you may give a summary of events. At this meeting, you may present evidence and be represented by an attorney of your choice. In the event the Contractors’ Licensing Board finds you in violation of Sec. 22-201.1 of the Collier County, FL Code of Ordinances. Sec. 22-201 – MISCONDUCT – Collier County/City certificate of competency. The following action(s) by county contractors shall constitute misconduct and grounds for discipline pursuant to section 22-202 of this article. Page 96 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net Sec. 22-201(18) Proceeding on any job without obtaining applicable permits or inspections from the City building and zoning division or the county building review and permitting department. The range of disciplinary sanctions which may be imposed are, (1) Revocation of a Collier County or city certificate of competency; (2) Suspension of a Collier County or city certificate of competency; (3) Denial of the issuance or renewal of a Collier County or city certificate of Competency (4) A period of probation of reasonable length, not to exceed two years, during which the contractor's contracting activities shall be under the supervision of the contractors' licensing board; and/or participation in a duly accredited program of continuing education directly related to the contractor's contracting activities; (5)Restitution; (6)A fine not to exceed $10,000.00; (7)A public reprimand; (8)Reexamination requirement; or (9) Denial of the issuance of Collier County or city building permits or requiring the issuance of permits with specific conditions; (10) Reasonable investigative and legal costs for the prosecution of the violation. Sincerely, Michael P. Bogert Supervisor - Code Enforcement Collier County Contractors’ Licensing Code Enforcement Division 2800 N. Horseshoe Dr., Naples, FL. 34104 239-252-2450 michael.bogert@colliercountyfl.gov Page 97 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net Date: August 21, 2025 Peter Kallie Kaltin Construction Inc. 18247 Royal Hammock Blvd. Naples, FL 34114 RE: Case # CEMIS20250002654 – 5334 Treetops Dr. F2 Date of Violation: March 7, 2025 Violation: Commencing work prior to an issued permit (ref. FBC 105.1), interior renovations/demolition; Working outside the scope of license, Electrical and Plumbing work during demo/build back; Failure to act following County staff's directive to address the rejected revisions. Dear Sir/Madam, A complaint has been filed against you by the above referenced entity. A hearing of this complaint will be held by the Contractors’ Licensing Board on Wednesday September 17, 2025, at 9:00 AM in the Board of County Commissioner’s Room, Third Floor, Administration Building (W. Harmon Turner Bldg.), at 3301 East Tamiami Trail, Naples, Florida 34112. Your presence before the Collier County Contractors’ Licensing Board is required at this time. The packet concerning your case marked composite exhibit “A” will be delivered to the members of the Contractors’ Licensing Board one week prior to the hearing. If you wish to receive a copy of this packet, please notify the Contractor Licensing Customer Service Office. If you wish to prepare a defense packet and have it delivered in conjunction with composite exhibit “A”, you must make fifteen copies and have them in our office by 8:00 AM on Wednesday, one week prior to the hearing. In your packet, you may give a summary of events. At this meeting, you may present evidence and be represented by an attorney of your choice. In the event the Contractors’ Licensing Board finds you in violation of Sec. 22-201.1 of the Collier County, FL Code of Ordinances. Sec. 22-201 – MISCONDUCT – Collier County/City certificate of competency. The following action(s) by county contractors shall constitute misconduct and grounds for discipline pursuant to section 22-202 of this article. Page 98 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net Sec. 22-201(2) Contracting to do any work outside of the scope of his/her competency as listed on his/her competency card and as defined in this Ordinance or as restricted by the Contractors' Licensing Board. Sec. 22-201(18) Proceeding on any job without obtaining applicable permits or inspections from the City building and zoning division or the county building review and permitting department. The range of disciplinary sanctions which may be imposed are, (1) Revocation of a Collier County or city certificate of competency; (2) Suspension of a Collier County or city certificate of competency; (3) Denial of the issuance or renewal of a Collier County or city certificate of Competency (4) A period of probation of reasonable length, not to exceed two years, during which the contractor's contracting activities shall be under the supervision of the contractors' licensing board; and/or participation in a duly accredited program of continuing education directly related to the contractor's contracting activities; (5)Restitution; (6)A fine not to exceed $10,000.00; (7)A public reprimand; (8)Reexamination requirement; or (9) Denial of the issuance of Collier County or city building permits or requiring the issuance of permits with specific conditions; (10) Reasonable investigative and legal costs for the prosecution of the violation. Sincerely, Michael P. Bogert Supervisor - Code Enforcement Collier County Contractors’ Licensing Code Enforcement Division 2800 N. Horseshoe Dr., Naples, FL. 34104 239-252-2450 michael.bogert@colliercountyfl.gov Page 99 of 303 Page 100 of 303 1 Michael Bogert From:Peter Kallie <pkallie51@gmail.com> Sent:Thursday, July 17, 2025 2:11 PM To:Michael Bogert Cc:Arthur Joubert Subject:Questions about the accusations. EXTERNAL EMAIL: This email is from an external source. Confirm this is a trusted sender and use extreme caution when opening attachments or clicking links. Michael can you answer the following questions Upon review of County permitting records, a building permit was never applied for or issued prior to commencing work, and a permit was required to perform the subject scope of work. What work was never permitted? On March 7th, 2025, the Collier County Contractor Licensing Department received a public portal complaint from Yanela Macias, property owner, for an expired permit, and commencing work prior to an issued permit at 5334 Treetops DR, Naples. FL. The only time the permit may have expired was after I requested a renewal and the time it took Marta Reyes to renew it, but I requested it before it expired and what work commenced without a permit. Can you show me the complaint on the portal On July 16, 2024, Scott Ctvrtnik, Site Plans Reviewer II (Fire) placed a CO Hold on permit# PRMFH20230416452 for unpermitted demo work in 5334 Treetops Dr. What demo Work? A. Upon review of County permitting records, a building permit was never applied for or issued prior to commencing work, and a permit was required to perform the subject scope of work. We had a permit PRMFH20230416452 B PETER J KALLIE is in violation of Collier County Code of Laws and Ordinances Section 22-201 (18), which states, in pertinent part, that it is misconduct by a holder of a Collier County Certificate of Competency, to proceed on any job without obtaining applicable permits or inspections from the City building and zoning division or the County building review and permitting department. To the best of my knowledge a permit is not required to replace plastic electrical boxes with metal boxes as long as they are not moved. and a revision was applied for which included the electrical boxes. I would really appreciate your response Peter Page 101 of 303 Page 102 of 303 Page 103 of 303 Page 104 of 303 Page 105 of 303 Page 106 of 303 Page 107 of 303 Page 108 of 303 Page 109 of 303 ....... . . . . . . . . Ryan Kloski Associa Gulf Coast, KALTIN CONSTRUCTION, INC. GENERAL CONTRACTORS CUSTOM HOMES License # RR282811144 License #CRC1331227 PROPOSAL 13461 Parker Commons Blvd Ste 101 Ft Myers, Fl. 33912 3/23/23 Re; Repairs to 5334 Treetops Dr. Pull permit, Floor plans provided by Association. Take up tile, sub floor, remove cabinets, tub, toilet sink and vanity. Install new Advantech OSB TIG subfloor glued and screwed per code. . ..... . . . . . . . . . Replace?, 2x8x12 joists and reinforce floor in living room with concrete pads and posts with a 2nd row of 2x8 boards under the existing joists. Main demo cost; Replace Unknown at this time Joists at $120 each Re-enforce living room floor Pay Plumber to sign on Install Insulation Total $16960.00 ? $1920.00 $500.00 $3880.00 $23260.00 Terms 30% on approval, 50% once floor is removed and balance on completion Once we have exposed the joists we will see what has to be replaced and we will charge the repairs at T &M With Thanks Peter Kallie Kaltin Construction Inc Page 110 of 303 KALTIN CONSTRUCTION, INC. ..... . . . . . . . . . . . . . . . Ryan Kloski Associa Gulf Coast, GENERAL CONTRACTORS CUSTOM HOMES License # RR282811144 License #CRC1331227 PROPOSAL 13461 Parker Commons Blvd Ste 101 Ft Myers, Fl. 33912 3/29/23 Re; Repairs to 5334 Treetops Dr. 50% draw on demolition Replace 19 joists@$130.00 ea Add center joist ledger in both bedrooms @ $1960ea Build rear and side walls In left bathroom Total With Thanks Peter Kallie Kaltin Construction Inc $11630.00 $2470.00 $3920.00 $660.00 $18680.00 18247 Royal Hammock Blvd, Naples Fl. 34114 238-253-3181, pkallie5 l@gmail.com . ...... . . . . . . . . . . . . . . . . Page 111 of 303 ........ . . . . . . . . . . . . . . . Ryan Kloski Associa Gulf Coast, KALTIN CONSTRUCTION. INC. GENERAL CONTRACTORS CUSTOM HOMES License # R.R28281 l 144 License #CRC1331227 CHANGE ORDERS 13461 Parker Commons Blvd Ste 101 Ft Myers, Fl. 33912 4/2/23 Re; Repairs to 5334 Treetops Dr. . ...... . . . . . . . . . . . . . . . . Front Walls; Build temporary wall to support roof and then remove windows and door. Remove drywall, outside siding and then remove the rotten walls. Frame up new walls with PT lumber because termites don't eat PT lumber, provide openings for the windows and door. Drywall the insides and clad the outside. Paint. Install the windows and front door. $8746.00 With Thanks Peter Kallie Kaltin Construction Inc 18247 Royal Hammock Blvd, Naples Fl. 34114 238-253-3181, pkallie51@gmail.com Page 112 of 303 Page 113 of 303 Page 114 of 303 Page 115 of 303 Page 116 of 303 Page 117 of 303 Page 118 of 303 Page 119 of 303 Page 120 of 303 Page 121 of 303 Page 122 of 303 Page 123 of 303 Page 124 of 303 Page 125 of 303 Page 126 of 303 Page 127 of 303 Page 128 of 303 Page 129 of 303 Page 130 of 303 Page 131 of 303 Page 132 of 303 Page 133 of 303 Page 134 of 303 Page 135 of 303 Page 136 of 303 Page 137 of 303 Page 138 of 303 Page 139 of 303 Page 140 of 303 Page 141 of 303 Page 142 of 303 Page 143 of 303 Page 144 of 303 Page 145 of 303 Page 146 of 303 Page 147 of 303 Page 148 of 303 Page 149 of 303 Page 150 of 303 Page 151 of 303 April 3, 2023 5334 Treetops Dr. Page 152 of 303 April 3, 2023 5334 Treetops Dr. Page 153 of 303 April 3, 2023 5334 Treetops Dr. Page 154 of 303 Defense Packet Page 155 of 303 GOEDE/DEBOEST/CROSS ATTORNEYS AND PROFESSIONAL COUNSEL r NFO@GADCLAW.COM / WWW.GADC|-AW.COM ReplyTo: Stanley A. Bunner, Jr. Caroline Axelrod Goede, DeBoest & Cross, PLLC 6609 Willow Park Drive, 2nd Floor Naples, FL 34109 Phone: Email: (239) 331-5100 ext. 134 sbunner@gadclaw.com caxelrod@gadclaw.com September 10,2025 Via Hand Delivery Collier County Contractors' Licensing Code Enforcement Division 2800 North Horseshoe Drive Naples, FL 34104 Case No.: C8MIS20250002654 - 5334 Treetops Dr. F2 Exhibits for September 17,2025 Hearing To Whom It May Concern: Enclosed please find 15 copies of the exhibits to be used in connection with the hearing in the above-referenced matter on Wednesday, September 77,2025, at 9:00am. A copy of the hearing notice is also enclosed for reference. Should you have any questions, please do not hesitate to contact our office Sincerely, Gonnn, DnBousr & CRoss, PLLC pt &no(rrae lfirtlrad Caroline Axelrod, Paralegal Enclosure Re NAPTES I FT. MYERS I CORAL GABTES I BOCA RATON I PENSACOTA I PUERTO RICO G D &c Page 156 of 303 Caroline Axelrod From: Sent: To: Subject: Peter Kallie <pkallie5l @gmail.com> Tuesday, September 9,2025 10:22 AM Caroline Axelrod This is how we found the Kitchen wall The materials are left over from another job I Sent from my iPhone l. /* !')F. t3 .:r,;\'St'..*{ 1 { I I \ 1 ill 5- t $ a Page 157 of 303 ,1f ,r f a: BUILI)IHG PERMTT APPUCANOH.JLcoru*vtuCrurhlkqrrrrrt Dry!?rt zfoibrth Hon dtil Dtftf,. tlfht, fL ill0| fr!$tst'lf0@3o+ ri*rrr rhi{ *Ffftrfur SSCil-teftfiit hfrlrngtsl Elrrrrrr-Enntf;EJ.lur{glktr*!: 4.Lf\ffitl tlSsdimA. FeilnitFfrnfrer cIFrd/ro t 'l'lrr91st p$sL f.5.**rhlt*ittt LCt: .(t"t -*ac {r,h 9{ fntr{.r Strrr 1 CI- Pm,krl l{irft:La JEbStni{ C.Lo*pllil* r.ttltr f4rr rA{(.L 5DFIFI,I: illn'L9. Jrrb*lrttst"Ele**rte,rm d t-.+.rfrd*r(*friUFIE,E t..l"Eu* 6ms&,&r:HrrrrrlO-1, P.rr!t*Sectiat B. Eontrattor lnforrnatim ?tlea !l*r*r"i.D3'lktrt*l ?&.?g'. sr rqJ.Dt{mc Or,(rytllr*drl r-{, .s C"+r " i ^tr.- Es, faffi*fln r:ffit Ll- n rttL( D;i&lsft r'rF rn tEEdd ef {3.ryflfi*fff rllrntry gx, Frn t f!:i ,t!il:r r,*ldry 6r lBeflrtl aflrrrr&.irrqfillr Fbrr" od#ttlrt tt olffi ri. ft,- R 5.&r*+. $*rL ,is Qrrt (e*- Lhrer g**r&S qL 5fi tilrthj(Ironl hrElort ,rtutJf'lln* [Jt I r(!r. E,tr I 8"16, Subcontrr&r: Cn{.s* AIJ flwtrichorrr hcff,uc ToralilurTtuofluk I Effi {5t'iryl ffi} t btif fsiormed .r*-. !rrr$/rt $eer ilo t (,rrr al tl*t *rl rtlraf\l|1.rr| S*<tirm F. ArEr dCtr$tructkxl Acrhrrf lWotk Are* Onh] rtutrf,flnr.$q.Ft.: tr.S Addmh.n. QC ttolrU*e/txt. tE FL:TordS{Ju -{ift- titr utr Er Hll* rEff, igl ttlt+ t.H oitv Oevrfu*ierr: 5eaolPbm:# F.6t I I rCiX'Frtt lJa &rcrtcnr LA 't D&tlrIlhrHrt-rr 5e{tim [, ferrnit lnformatinr F{r,tRoxt - Page 158 of 303 COLLIER COUNTY GOUERilHEHT CROWTH H,I!IAC!}I!I{T DEPARTTiEHT I EUSIIIESS CEHTERe80t, f{. Horrarhor Drtyr, ilrplrr FLl{ro{ | Fhsm (t3g} ri+rem Initlal Inromplete Hotice Incomplute trnlHal Submittal Hotlce April 24,2023 Diane Baldrieh RE: Permit Nunrbw Pft,MFHZ0?304 I 6452 fl+cription: R + R subfloor dm to ru from water drmagc ref: CE$D?tt23tt002S36, PRDM3E3O4 I 4260 5334 Tretops D*, rurd$ , Naplcs A sufficicnryS_view of the submt-n1t pckage for the abEva refer€noed rpplicarion indicatcs the following itcrne art defiDient. thmo items rvill necd to bc sri6mitt*d m mqn as possibk ss that $E mxy csrtinue tn proctss your *pplicrlion: Revlswed Ey: Erooke llyhaten Phons: tzSB) 252fi)gg Email: Brooke.whahn@colll+rcountyfl.gov 1' Archllmtural Plant - please rwr* wili rnisahel shaetey fo pluyide you witha valrd drgital signafi,ne A final sufficienoy revipw for pcrmit applicalion PRMFH202304l6452 has hcen cotnpleted *nd daemed insullicient. Feilurc to rcspond to this norice *.ithin ? calqndrr dal's will result in a Final Incomplete Noric* rlrat allonr for an adrJitional ? dals io respond. Failure to respond within the ahrementioned 14 days will rcsult in this g.nrrit application being set to a 'Denitd" stalus and is considenEd closcd. A new prmii tpplication corering the pmposrd construction shallbe obralned before proceeding with the *ork. For elecuonie suhrnissions, crutstsntling docurnents can he submitt+d online. ,, , ,,. I : : Your applhation can be accr$sfd here: h I I 1Ir ' ,' jr: ', I r u rli: l-s:lliruruu[-!]_.,*cU lLLU"\iLqU \l ch: Page 159 of 303 Brh: Mry 19.2Ug Gontrst tlrmr; Diarp Batdrhh Addrmr: 1?10 Goldcn Gata BLVD Esr Clty, 8trt€ Zip: Neplee, FL 34120 COLLIER COU ilTY GOVERH]qEilT GROWTH I{AUAOEHEHT DEPARTI{EIIIT / BUILtrIHG EEI'IEW E TH3PECTIOH DTYIETOHzBoo N. Hor3.rhffi Drivr, Haplta FL t4ls,r i Fhona (r:tg) rsz-z{zB Outstand i ng Corrertions FERillT ]fO: PFIMFH]oasOtl B4gIOi APPLICITIOH HO: PRMFHz0?ar)4tE4E2 JOB $lTE ADDRESS: E33t Tree@e OR, tUrritl, Nadss *mrl[ dbatrlrlch6@E Bt. Eom DcarApplicffit Plant t{s{td[ld wlh tlp ru{einncert porm[ ]nliE b*n rwbrynd. fr& arc unabh to wrorn yoi$ p.rmit .N631ion for fiqrmo(rlhdhaEd batonv. ForltrIhriloar g{urlHrd friorr,Eft lrrr AtrA Bfurrffinf frlhti' E*tdxnlluh mu* bo autrfilct, h lhr rgna c*aloi''rnd 0rr drarqne murl br drqrffi.r CffieSd dsarmrnB mu* he u.Dm&d E$ crytrphh fitB ("th t|riil;H;hleb ,qtrtr fle h€,qcchdah*e&). subn!ilH0t omtahhrg hu sra w*md lnafue nin m lsrunrrd tdi*uf#fuirltr '4' '";ri!t+n letter r:{ r*s[ionsE sljrfifi'rErlEtr€ lh* e h.:ng*s rnadu to iie!.ir*.*ss each *orre$ti,rn fr,ilr]Bnl m[5i *etne:lCed ir foUf feslhnt,tl* - Farjlr* tc ir:elucle *, ,,*,il=n lelier oi ,uSg.oiSe lr, 1 feCUff in * r*;*c:,or,' AiEr lutr narxrbmittel b praetad sre decsments ws H lwhuud egeln; atldBenrl orrc6rx*a* mry bt l&fittrcdthmughthir Fm*au. {B FlEryEI'$al: R + R rubf,oorduc b rot hom water drnagetut CE$O2EB0QS?B3E, pnmm0ffi0+t 4160 53&l Trcltop DR, (t nttl , Neph$ Rrl.stod Rrylrw: Etruchtnl Rsrlexftrtrhwld Ey: IYlillrm Errtt Phpnr:239-2$t ?t$r Emalr :Irufl ilam.cnftecor Berco u n tyft. gov conEction crynrnent 1: FEG-E zth e0t0 cheper tg $oils and Foundations Pro,ridc datail{br bundElion/support post repeirr urder lhor, ATTEHTIOil: Collier !9unty Plsn RwlEt, end lnBpst{i$ns rouline[ reviesa all outatanding pcrmit applloalone ln order lo delsm{ns 6,,sir 3.Etuf ,Ths rsviarv p.rouc!,s ingr#?s1appnopriata rasfionses rrarn t'e nglmit;iFlicant ffi;; tho p*rrnit cannot bc Epprovnd.when tho BPPlicant is advbed of dtfriimim ano does nor rrsrcno ilthtn_t8tl dryr wilh mrrectsd Bhrr or an ppcallo trc@ds Eniorcenent Boerd, the p€rmn sppfiffiton *i[ oemme vtid Es per Gotttor @unty ordrrrsrsr lgCIl4lt, .srrlfon,10{..5.1,1tE t&t.6.r.{ frl rmendes. - ' Page 160 of 303 BUILDING PERMIT REVISIOI{ FORM ilo n. iEiSErilrc Dftm, fllPrEl,. fl:r19 tux'l rs+rqm 'r\tll b bE icd tb t+*nrrHB . .Ar:=dentr+l I q2 tkrr'rc lsilrtfrtih/S{ghrl lr {lnitr l}.luttrferuhl * Currt*cd Icb Strrgt Addresl,Farcel/Tolh I Owner Harne Cwp*ryl{am: RAtX*l lis-*4,ur^1,.ttrtq. *--fu$rillo. :"oNrE-Euldc Qr"ral he+/thpnreF{nl''ler: ;}t'dfl slatht. Axerrt/Conrarr aan*e: *1=c#, Hc,tt r- - Consany Addrr ;r, - Jfr 1,4 ? -$, tf} ltloinlgtttrx-.A-{u.f- ttll FaI r-.4)rfi c#*co,.,arr --A-ra.A-...jr.C**tr llo"*}rrf,,lt 0$Bit?rrr fl.t EgrrEmil$i,Irsr8f lg.ouoEtr ufirH $t trsitlEnrlsttrTllE s00Pt or rvltx {ry r lrUop:+ h) nnf prlrfr.ll l}OrOOn OI lht hFtry.ngulr} rerrrlt rn Ox,nfflhrFfloi'r; lgvri,rr *hirh ody rr4intr oa }'}f rrnr.&Jmr.r:tncr0e Itl4'61q: alg.r:ly ,r rJrr r l* oay rhungt' rrt t,\t lecor'ir snrtf1r. yt lt.r ', t 'rl fl r. idrt; charuerotriginerusspe elfrtir fuhrutd-.lt-bn{t*. Emrl:/fattre,"5l G ?'"*at,e-frfr*r>l'fi, l.*rt*. r5ft) _l tr t t c ctrt Id: Lscahon Perrnit Numbcr .qq$r1gor&lqryr-BqrlCeil!hlrre$or Project Nrme: AdditionalS ft $dtgflnte'tl:r: - Addltto.ttlfu{tor(onstnrction& .l- rra} - -..: =: Addrthnal 3q fI Hon{ryrnplExlrrror: f PrnsmPru'ruer : Rooffr4 : i Septr lSlrunerr f PerrnUvlffiaarr t-. Hrmbrg flEhdrial t' i[ffiuolrage f Frleahrnicai ti*ruarra Qualifi er Ac$(nowledgement of Revisfon Suhrnittal Cc$rptnt Nlme +*+dT ro -€sr.:5*r.&r-al:f...*_**-* Qt,llifier'r Narne. d.*&t* q<"*ff* ftshft*rt rsnrturr 5iaeol - .. trJ Carnryot -.&*AcX, E.ME* prsrrreor [J e5-. asyrThE tgrEtolng lnrtnment $!r dfiordrftrd befre rne ty mcrnr d , , 20e4 , bf lprinld mrnr d orvno or quntrtlrl Sr.rh Ferron(rl NotNry &r$(ilEt t{rccr ardrarilr bo. ts' fuF Far,.roru{! lnfrn m nE I. mrprn*reO a cunenr drir+nEernre - - rurfyuAxeO N0l&,y !Erralurr a$kl4ffititErHl ,,:] tti .r.rl 1 j fuAtr Dor{gltt tm ic(8, FotSTr,l us olry hir.tx{rE,'BN(TtH Arldinonalfserr &rldffi$- [rc:$ OeyrEania*n *-5*t$ ol Fla.E Cq:.-- -r?ra{ Ftmre -4f:-"LEf. 0nlne6166r**rt* - fhlRIHr, . , *._ -. - E$rd.'{ Fflx,rEF'ep! forr 1 1 Pg1 Page 161 of 303 rrt(.) (}}5{ tso c 13$(] 7J l1r Ef tr! r7( I i z fl rq {t F {!e,L f:F t.vtaQ m \ L 6 > sI3 C l* \rq \,it$ "P EI +T FI rr, 3 (\. t ( ( I! L ,T\ Fo ? aer .,:, ! r ! rr, rt\ft 3 ;rr ?( ,ofr I ,, ) ) l q iFISt qr'lE- slt F= *r $'r- ( \ {il a ,al ^!l!. .t L.*{( {xrE \ J \ II t = a ) q+ =gtc.t.Z ir il *.? I e t: t II l.J )* Page 162 of 303 PRLTFI€0Ao4tat520t Ftlfl tllltl(lcfttr} Ix EF[t(T: fEC ?* Edirion Sl0 tr./ lDm sup2 4!4qlEESEt J:I34 TrtdoFG DR. (r.krh), Nsste5 EQI-IQf, ??.l6lBm03 I8F{E$T,!!II0$IIR+ R $filloordulroru Fam mtrrhan3c y!i!8smm30002136' FRD[u30230d1+!60 . fERMIT tliciihfs REP,LACE$c wA[L U!{DEE DEuo rEnMIT.REV0I- Rrbuild Wrlls. 5334 Trectop DR. (llnh). Haplcr oliltltrf, rNFoRMrTtoN: MACIAS, MCKY L ?A}IELA T MACIAS 5334 TREE'TCIP5 DR AFT Fd NAPLES,}L 3{I12 AnF.A OF tYOf,.K (SflFTL 0 P,[&\{IT *: FRfrlrn]qils4rh*srot DATF ISSIIFjII Jrme06, x0ll fiEIBArJS.FRftlST: REAR: LEFT: R.IGHT: EL.QQD.TNUE AE trFLt fiR: WATE.R: IQII{TRACTDA I}'IFORM ATION : KALTIH COHSIB.UCTION INC. 18247 RCIYAL }TAMMOCXT BL}T, Nrpler" FL 3{lt4 [239) 25]3t81 GOLUTR GOT.IHTY BGARtr trF GOUilTY CMXIIIIOI{En! PERTTIIT pERhtlTTypF: Bui].diug CE.RTIFICATE #: r,cc?020000fl?l? Page 163 of 303 Ihfrr: Jub 18.1S23 Gartrct l{ema: Eliane Bakictr AtHner: 1?10 Gdden Gate ELV[) Exr G[y, Strtr Z]p. Haples, FL 34120 COLLIER COUNTY GOVERFI IYIEHT trROWTH HAHAGEi{EilT DEPARTT.IEHT / EI,ILDIIIG BET,IEW E II{SPECTIoII DIYISEoI{28m H. Horpuhor Drlnc, Hrplrl FL 3{104 * FhonG {239) 2s2.l4tB Outstanding Corrections PER.HIT t{D: PRMFH!1023&fi 8,[5402 APPUCATIOH l,l0: PRMFH2@IEI+i 6it5z JOB SITE ADDfrEBS: f^331Treetsps DR. {Unir} , NEpt* Emrll: dbaldric,hE@aol.mm DeerApd[eant Planr eubrdttstl u'ilh ttt rrhlrn$d Ftrmit hcvc b*n rwkxysd. tltla are unoble lo 6pmw y6ur Fefinlt aglaion fur ilEraaaon(a) hdlod€d beH$r. Forlppficatlom &&mffiedfimuge ftr BIffi Efinnilffirg Flortrft. Rsrubmifiab mr$ bl erhtrithd h lhe rrrtc crsdon and He $rrngae muat te dou&d. ' GrytHsd dDcurnrnb mret hs Bt&miH as mrnpletEfiha (wlttr trs eonffid drseftB Cfkdng th6 rtFcbdshtffi). $ubr*thta DonEhhg luat th€ aorm{tgd rtrtot* r#iilbe rpfuftrgd ar tmuffidsnt, ' r A ij"'fillen letter,]i Ii5]DltF* alri't-ltl6lJr'i; 1f rd Llrcrrgi-s rnadu to *il,jr*ss eacl: e-+.re [.ti*r ecm,-n,:nl mu*:: tr8ir':'uded irr 'lcr.tl ,*5ulr!'i'ri!ie! Firlrrre tr: inilu,Je a t;'iit+n l*|:trc,f F*Spnrrse *iil r*sult ir * r*j*r:lrurr. Atrter yourrx,rbn*fld b procr*crd thc documontr wil be rwienpd agnin; drtilbnel o*dndps mry b, idsntfird through this pmcasa, JqB=EEEtFiEIP.tl! R + R cubfroor dut to rd hom waler dxnagn rsf- CE$D304i0002836, PnDue023tI414lB0 - PERMIT tNclubEs REPIAoTNG vt ALL UnDER trEillto pERiltr. BEVOI- R&lild $th*r. $SS{ Troo,top* DR, (Unh} , Nepte* Rrlected ftwisu: Slrw*urrl Rrrhu hrytmr$ Ey: Wtltlrm Enfi Phonr: 238-lE2-28t{ Emsll :Itrfiillam.Gn@coilhrcoun6pft. gov Gsrsclion GornrrrEnt 1: FRAilIIHG/FAFTInON Y4L.! DETAIL As required prr eactiwr 1oLB.S of lhe 2020 FBC, ptaaca flovide a tu}l hrEht framing detail to krclude maleriel type and ktenirs strl'wiru iimpriance-iitn *in {,6timilia uta build in g conatruclion htra. ATTEHTIOT{; Cgllier 9Punty Plan Raviiif, and lnrpaclions rcutintly reyi€r$ds sl! outslending parrnit epplienlbru in order io dalermlna thdrstatug" The revietu pro€ls indudBs tpprupriatc r*$ponscc fiom the permtt itipticant wiren ths pnnlt cannot m jfpouao !tr'9n !t q appllant lE €ctusd ol ttefrisnciet end diea nol re*pond ritnin ttO deyr wtttr corraiteo pkrr or sn ryffid 16 thaCods EnlorcBrnenl Boatd, thi penfin sppltsEtion $ll bemm6 VoU Es per eoloer Cofiry a;r6prrs1g,3 2ggfor, SiEiroa1od..8.1.1 fo l0ir,i.t,t frr umcndodi. Page 164 of 303 le;t'u {''m{.r.orr 5 3s n 4P#i61 ' U L- r.*3lt llltt \-Sryt\rruB Ut tJGf6 dt-ll 5v j.rt+ tI-r rJtr f$G+'+ fnno freoE {o cE'r'r r't , ^rf, otsn'so r }}$' $f*str lc ft l-{.fi, ft*r l.'tr ;irrrSr r *atct! t*i ttr+* f. *sl {,wGtt,a )5* 3 :rfir$i *t! to &o ai €a .3,1. h{tr urrS,r$ *s fryri Cfrr I lYft .* r"rrt{t .l}r*tn k rJ rftr ll'rrrL'irrh', !l $r,rf.t 8o t*' .fftrlt .5*.*,cn flo' oi " jrts; {,tu - t{}3a $qur,> p$r*rr-. $ !I{r-;''tlT tG**D rgr{rfQ,.Zf S SRIJ F €rn 6r+*g*, fx+ .Snt'r'A\L I rJ < TG t't{era6'..l r''r.t $rru' af }tf t'r4t + fpact "iDrF*rf]Jr}}rttHarfcFrrr-$'at*of,&€frn''rltttg $*rJ,6+t,t.lrJrftr4*,.5,.r"tqt*.r*.tE?uetJu*u*a*J5FTf,'l,. il€l,e.Efeo0rrrAQe.l.*fr*t$r9cr+6r-tlf&$#rt-*Ba*g+ L)r.* f,o* Crrreut [Ss'n Brrg $r'tt''* r] Ffflruc{ '5H 1xe 1*rf*cnrrf ro''rtr 5*'r'r 'rr&{€r (*E'6.t lo* ("t" I JSct Aq' i bt) n'of Hau( <tr e$tra"L {r*t zJqlA- 3'rr i srl *$t c*oft a $turt vd I tl iyir +lu l. Gel SO3 ' i*rt L)*'- bB r rq9cif t t*"G *) r,tre llorlcq' 'pu;it r*.16 'vrtl*? ft-r! *E*.rrr, 'f o +fi{ ' 9} five*o Qaae't* *ef '$G.tr'na ?+tg t*i S.l f*( ?gp,rilt^,{ o* 'fg6,G/'qrg g*f*.,''}i f{e}f 6^'+t..ffi}t' r-i J$rFilI.1+ lrr,Jrt, Gtqf.rCa fnr..<n *x C*l^rs, 1r,,tc'r' {alt{Us t3 B?*'q' $wnerrsrrl 'r1e1rr' ft*-;.{.r.d5r+ (v,G Co.rst r } fr*t Erl+rEq' FfiF}t#'-t' Page 165 of 303 F* I -A OBtS{rrft. Err*# }.es 'Jrr' trll** $,t ci 'r" t i ll' #fitrlr dtr, I 1!t ?{ firld- fttur**r'* l?'..frfr r.h, Sf t'{t " tl' &;lf [**t*L lo*t.JtF+ Cu+crr.{} 0orr l\frrtiBt" r $P" 60.^rsfgfa Sr*rrte' t lr*) H 4w<*, Dt' h' shP@ Page 166 of 303 9/{,126, l1:5tAtt{ 06/05/202i Response Letter 06/06/2023 Approved Flans (PR) 0ilAil2023 Letter 0Vl18l2O?3 Letter 0711,8/2D23 Applications Fcmttltp$Ea,itrn $tduo - Colior Oamty - C**llar Pona Hamm CorrectionF BFsponse Le$er, (ResM Treetops DR (Received tpdf} AEproved Csnstruction Hocuments Cofirm$fqiA| Csmbined Fefmit and Inspep[ion ]pb Card Co rre c&j$fl ukehtelHFR .; CI utsta nd,i n g Co rrecti o n s Bate Uploaded File Type o7/18/2023 Approved Plans {pR) sub4 Revision Constructlsn flafls.{RpvEion PlAtr- 5334 Treeto ps-n E" :.H[spfl tsd*ffi $Fqjr4ed L pdf] 08/21/2CI23 08/28/2023 Letter Approved Plans (FR)UL 263 U332.Bdf Payrnem t 5l i g;Bs.uisistril Ee) CI9/1.312023 Recelpt 09/13/2023 Response Letter Recei Revision esnstfuctign Plans (5334 Correctlons: Prepared {ReceivedLpdfl. --".1 09/13/2023 Approved Plans (PR}Approved Cnnstruction Dccu,rn Et1tq Corn mercial AglL3lZOz3 Letter fi 0711617024 E-mails A7lL6l2O24 Docurnent AU18/2024 t-etter Combined Pqr]mit and InEffi Q Et{ O P F B.I"IIJ". RE 5 SSilIreSIo.p s P n I l\l Fo RJt4 ATIo N # FEMO FFBMIT CanCr*lAHon Authqrlzatlon - Anptlgatlsn pdf I I$|lFORMATION Extension Exf:qutive OrdFr (QeneratF Letter Efiension Executive Order). fut C'w;,(,al'- !l''lq'tr-ra>Lc 4e fr€"': 7'{ ? L.,x*l htpr:{/arportel.ollkroun[tfl.gotfow6.t /ylrib]P.irfll'J5'tntut?psmitld-55I1I0 3A i sub4 Revision Form (Revsion 1- 5334 Treetops DR - Prepared (Received ).pdf ) I Page 167 of 303 5/485, tl:564il1 F"* luptoa Prm*tAgticatirn &s0.8 - Cdlhr Couty - Citylfim porral !-t I TyA rJ+lrj A8/L3{ZOZF Response Letter sub8 Corrections Res pgnEe l.ette.f 8- l 3:?5 slgned -pflf ) a&/L3l2o2s 08/7412A25 Approved Plans quhF,Hevtgtory;cpnstru6.tinllptans (s3J4 Treetops FlFals(PRI Reus slgned.pjff]. Approved Plans Contracts.odfIPR) 08/L4lz.Ozs oelrgrzois a;ter EaysenLElip-BEyilians-(g&. ABILE{?.OZi Receipt Receipt for transactiffi : 2025-074?*F Appruved Plans (PR) Electrical Pl an s { 53 3q Treetopg_EledrlcAl-pAgg - Erepard.pif) 08/2S/2025 Approved Plans TPR} 08/2W2A25 Approved Con st ruction Doc u rnH n ts S0rJn me rcia I 5334 Elec effinmplifla,pdf r*F.r/clvrdrl.ooriarwrntyll.gavlcitylfiarralcbJparr*dstaers?psrrraff*E6i.l2s sr5 r .rrr.i.!E Page 168 of 303 Caroline Axelrod From: Sent: To: Su bject: Peter Kallie < pkallie5l @gmail.com> Tuesday, September 9,202510:10 AM Caroline Axelrod Re: 5334 Treetops Dr THiCaro ne, this is the emaiI string yo anted o you stitl need me to come i On Wed,ay 17 ,2023 at 2:59 P eter Katlie <> wro Good a ernoon Lissand ra, t s letter is to inform ou that Permit PRD 20230414260 w I be used for de olition only Rega rd s PKattie From: CorsileLissa ndta Sent: Wednesd ay, May 17, 2023 2:32 pM To: pkattiesi@gmai[.com; peter@ ka [tinconstru ction. com Cc: KovacsSteven Subject: 5334 Treetops Dr Good ofternoon Mr. Koliin. We spoke this morning obout o correction on Permii#PRDM2O23O4|4260. This permit is for the demolition of the domoged front woll ond bothroom woll. considering thot ond the foct thot you olreody hove o permit (pRMFH2o23o416452l for replocing the subfloor of the unit, lhe best option will be to use this permit to repoir the wolls Thot meons opplying for o Revision on Permit PRMFH2O23O4i 5452 including the "Repoir of the domoged front woll ond domoged woll in the bothroom" ond using the permit# PRDM202304i 4260 for demolition only. Pleose let me know your thoughts ond I con help you with ony other further questions 1 Page 169 of 303 Respectfully, Lissondro Corsile Fire Plons Reviewer Il Growth Management Department Building Plan Review & lnspection Division 2800 N. Horseshoe Drive Naples, FL 34104 (239) 252-7517 How are we doing? The Buitding Ptan Review and lnspection Division wants to hear from you! Ptease take our onl.ine SURVEY. We appreciate your feedback! Under Florida Lavrv, e-mail addresses are pubtic records. lf you do not want your e-mail address released in response toa public records request' do not send electronic mail to thisentity" lnstead, iontact this office by telephone or in urriting. 2 Page 170 of 303 PERMIT APPLICATION CANCELLATION AUTHORIZATION GENERATED: June 16, 2023 PERMIT APPLICATiON NUMBER: PR_DM20230414260 This Authorization is to acknowledge the permit application cancellation request has been approved and the permit application is now "closed". Pursuant to 553.79(15a)(3), Florida Statues, "The term "close" means the requirements of the permit have been satisfied". IMPORTANT- lf the proposed work associated with this permit application is to be pursued at a later date, a new permit application shall be required. JOB SITE ADDRESS: 5334 Treetops DR, (Unit) , Naples JOB DESCzuPTION: (Demo) Termite damaged front wall and wall in the bathroom.***DEMO ONLY - rebuild under PRMFH202304I64S2 *** 5334 Treetops DR, (Unit) , Naples CONTRACTOR: KALTIN CONSTRUCTION INC., Address:18247 ROYAL HAMMOCK BLVD, Phone:(239) 253-3181, State Reg #'s RG291103895, Licensee #LCC20200000737 OWNER: MACIAS, NICKY L YANELA T MACIAS, Address:5334 TREETOPS DR ApT F-2 Note- If the proposed work commences on or after the issued date of this authorization and there is no permit; Collier County Code Enforcement or Contractors Licensing may be notified to take further action to address apparent safety hazards, as appropriate. lf Voy have any questions regarding the above comments, email Building Permit Resolution Services at l]l'}IlS'r!'coIIiercounrrfl.gor and reference this authorization. 28oo N. Horseshoe Drive, Naples FL 34104 | phone (239) 2s2-2493 Page 171 of 303 afuar-r*r4-1^_.-i_ GryS MaDOehrc.@nity D.vdop'd6( c)@ n..t Tl^,s'c-rr can be uploaded to t.1e oo.1a o-ce tl.e sLDContractor ccnd Iion has oben aooed. Need Help? Gl,'1CP Friblic llDrlai Permit Subcontractor Affirmation Permit Number: PRMFH2023A416452 Job Site Address:5334 Treetops DR. NAPLES FL 34113 The below named subcontractor hereby requests to be added to the permit files for the building permits tisted above. I hereby agree to comply with the County Building requilements and all provisions of the laws of the State of Florida, and all regulations relating to or applying to building, plumbing, electrical, rooling and air conditioning construct'on. I certify that the information pertaining to my trade on the applicatlon is true and coffect to the best of my knowledge and belief. Providq es applicable to scope of wofi: El ElectricalContractor tr MechanicalContractor tr Plumbing Contractor tr Roof Contractor B Septic Contractor tr Low Voltage Contractor tr Pool Contractor (if permit applied for by a general contractor) f,l Contractor Other Ljcense#: ER13016226 ouarinerName: ISMAEL SANTANA Qualifler Slgnature 5t17t25Datel Subconkactor Lisl 9/2023 Page 1 of 1 conrpenyN"r" JTM ELECTRIC INC Page 172 of 303 5334 TRtrtrTOPS DRIVE WATER AND TERMITE DAMAGT REPAIRS FOR Condominium; Naples, FL 34113 afirFnrl Nnrs. t. A[ cuailc T0 8E ttlPlcl Rt9sTAllT. 2. Ftom ulE L0 D ll[{. 60 Psf, cmff)ms rm PsF, rNo uN. 0E 0 L0A0 20 psF. J. AII IOfr) CUIPONSIIS I}I OIRTCI CONTACI ITITH COICf,EIE $IATI. 8E PRESS',RE IREA]ED. 1. AI1 BAIH ANO DRYER VTIIR $IALT VENI IO II]E EXIERIOR.4 AO PLAN REVIEW DATA PROJECT LOCAIION: 5334 Treetops Drive Noples, FL 34113 GROSS SQUARE FEET: 864 SF OCCUPANCY C|-ASS.: GROUP R - RESIDENTIAL GOVERNING CODES: BUILDING: FLORIDA BUILDING CODE 8TH EDTTTON 2023 MECHANICAL: FLORIDA BUILDING CODE 8TH ED|TTON 2023 PLUMBING: FLORIDA BUILDING CODE 8IH EDTTTON 2023 ELECIRICAL: NAT'L ELECTRICAT CODE 2o2O UFE SAFETY: FLORIDA BUILDING CODE 8IH EDrnoN 2025 ACCESSIBILITY: FLORIDA BUILDING CODE EDITION 2O2J ENERGY: FLORIDA BUILDING CODE 8TH EDrnoN 2023 CONSTRUCTION CLASSIFICATION: ryPE lll - B WOOD FRAME CONSTRUCTION BEARING ON CONC, KNEE WALLS, PRE-ENC WOOD ROOF IRUSSES WITH PLYWOOD ROOF OECK AND FIBERCLASS COMPOSMON SHINGLE ROOFING. ALTERATION LEVEL: 2 EXPOSURE CATEGORY: C FLOOD ZONE: B ULTIUATE WIND SPEED:170mph NOMINAL DESIGN wlND SPEED: 152mph Edwa rd B 3;'J:1'I'*'1"T":I, Bon d u ra nt ?il'; i11.9il' AO COVER SHEET C1.1 EXISTING SITE PLAN A1.I FLOOR PIAN A2.1 SECTIONS AMD OETAILS S1.1 FLOOR FRAMING PLAN S2.,I SIRUCTURALOEIAILS EI.I ELECTNICAL PLAN M,I.I MECHANICAL PLAN NOTE: MECHANICAL SYSTEM lS oUI 0F SCOPE 0F THIS CoNTRACI SHEET INDEX ARCHITECTURAL Edrsd ErEdlord'Brad' Bondurut Eoldurut lrchitccturc, LIf l?$ Rddo.r lr. llodc. tL J,tloJ &odo8oitdLdr.cm 0ffi6: 2J9-9J07-7270 C.{: 206-96J-2606 SCOPE OF WORK: I. REUOVE NO R€PtACE ROTIED S'8ttOM 2. ItiSIA! FOOIIIIGS ^NO PINS IO CMRECI SA@NG o0sllNc trcm Ftom J0sTs. ]. REIIOVE IERIITE OAIIAGED SIUOS IN U\'ilG R00r ^l{D REPUCE r$rlt ilE[ STt05. 1. Rtlrolf ItRutTE oAIAGEo STUoS Btllrilo IOUT IN IIAS]ER BAIH A}IO RECUISIRUCI UL ASSEMELY UJTE OI'I WAIT OF 8AIH. 5. RIPIACTD RRE RAIED OR}IIAII OAIAGEI) 8Y OXilERS DTTIOUNO{ IN KITOIII. 6. Rtpt cE 7 Pt src qjruT 80lts I|TH n8E RAITD IET t- oilEs. 7. tilsl I Ntf, sflTcHES AT FR0{I 00m X{0 RTPIACT ONE q'|.lIET UNDTR FRO{T TNOOI. COVER SHEET ro @N LOCATION MAP E}ONDURANT ARCHITECTURE D Dlt Page 173 of 303 -: U N d z J C 6 Oz =a @ i[I] ,'( !J tr l F l,rl : I o tr { Fz trl oz o m c! b! ttq) o0 I 0) a bn q X Page 174 of 303 a(nQwitrjit!C)2rtr=> 4I rY-N -t, ^/s ^(]-^LLU_JZLL-E>OLJLJT!Olr-[L(JOa 4-z(ti..rr!= 56*Ex --r = ^i95t_ffiniz-(x'-.=-.."9:oi ,=-=Edf,(r=z(-)(J =Cl Coo(u E=cf Co(,o E u<mFUN =Ena<r EqrerUui:Io<20[=uai:0.3 i" =ob I<oi >*o >oS; i:l<aEo g2g1'1 161 6uusrx3 lleM paleu JnoH I @ iCI:r { { ]w UJ tr tr F () lr, : I u tI Fz tf o z o m o z)C e 8ot ox^uot'J^<-u^- 38:EE;= :;5F rt; EL o* o6*s2*fitpF<,:;6ob Hq 5 E"'J-v YUli^ !!uu-' 2a oL x iuo a(.) u<gz += <= Far --r0^o =2ad =o=#5Y --- Fl,,u2.2i<coc0 uc)O 5cUE , o;Oc: oE= .oU o q.eC! c;! =L E6o!! Eo oo c.j .=q f co o E J l =oI Page 175 of 303 i-il 6;< tsk J @ @ JJ =oUF E UGE e o 4 z Fz =z EU6 J =U6 J)- E C oz = =U F Z frf oz o m ld tr f F o tij : I 0 tr { zaE J =6 =FF @ 6a Ie @E) zo =+ OJ FO udx$ u@*=ts=@'€*>O J O d F d o @ @ o - N .[II, J N = dz J@ @@ I 6 u E J = ffi \\ffi ra . t= ;ir 5;-E o9! EASE:3rtb=rg;l ;*1ff -l 2 \i, ?;! Page 176 of 303 E9o}DolOJ taLCfE IX_uJ Adjacent Unit Adjacent Unit NEW 2x'12 WOOD FLOOR GIROERS EACH SIDE OF 6X6 PT WOOD POST TYPICAL EXISTING 2x10 WOOD FLOOR JOISTS @ 2'-Q"o.c. TYPICAL REMOVE & REPLACE DETERIORAIEO WOOD SUBFLOOR W/ T&G CDX PLYIVOOD. USE 8d RING SHANK NAILS O 6,, IN EDGES AND 12" IN THE FIELD, 2x BLOCKING AS NEEDED 2' -0- x2' - 0" x1' -0' CONCREIE F00I1NG, SEE DETATL r/S2.1 ta*W E}ONDURA.NT ARCHITECTURE 1 A2.1 Adjacent Unit Existing UL U378 1 Hour Rated Dry6r WH I i=J ; -l I t, t T I -l I U tr<U-l I l-Itr tl_-,/ 1 -tl -1 r u -t -u / s2.1 I L I I _)l]L I -) I L ixt ll I J I FLOOR FRAMING PLAN REV 2 s1.l NAPLES t2 auo 25 ,,-:.-,:.... t"B:i #ffi\w -_J tr Page 177 of 303 +1 FRAMING DETAILS 3 s2.1 Cross Section SCALE: 1"r1'-0' 21',O.C. 3 @ i,b;6 E roEda{, dtroc. IEA/pm}g{d6 1A M5g 16' . lE Glnc6 bord 6 2r St 6 C tr O.C.Rl} ksjci,*+m trhddJu' o.c. frr) E,'tt C8ffing tlffi dd Rqtae Clrl$E*.d tl rcH, a dodiB 82tt'OC Typical Partition Wall Section s,lrt du? R.dp &ty D.t inlrd 410 PtFkibad qFrdtght iR 2tr0 PI le old widr I 2d EIr d 8'0C rLlgfid. sc.b: t{Ig A,FlCHITECTURE t*tN- ElC)NDUFIANT,,a.:::.->:.. i"mri "::-i!'''' /ffihw Page 178 of 303 D.W,36".Ref Oryer or 3m \ Q- 0,, ELECTRICAL PLAN REV J i5lTd-E1.1 Adjacent Unit REPLACE SEVEN PLASTIC OUTLEI BOXES WITH METAL OUTLET BOXES IN THIS AREA Existing UL U378 1 Hour Rated @ Adjacent Unit =o*sDfa_J6J(o LC)Fo.t2IX_u At EtffiE TO Efl MEC @I f 5h.bh,Fq,kl4,de ffiErglFffi. rffE0dr0E & Wdd.l ilrioL 210l (^) 20s rCC 2.Ntqrrd'ffiffir 5hd./6hltd.ffid&lr&frbtry Mpdkffi 3. A llEY 1trr rr roAffi. h b. MEdHFr{d.6.ll 2gr0E. a dQaagbd.oh@ddffirbh Mrqalgr5iff. 5 kFr*g*(hbrwlE6drgdmd4.6{dHf €o..8 6@.h,ffi( tsrlr. d b6SlmFtra zrg,lz @ t€c.!.ffiffiMgffitu.a.rr. NOTE: SCOPE OF TLECIRICAL WORK lS REPLACING SEVEN PLASTIC OUTLEI BOXES WITH i\,1ETAL OUTLIT BOXES, AND REPLACING IWO SWITCHES AND AN OUTLET BOX IN TRONT WALL NEAR FRONT DOOR E}ONDUR,ANT ELECTRICAL LECEND $ c 0 0 m] d" d' {t 0 as o 6r F o oa 7a atc 6 Dql 0 X * ffil ru shm 5 f,rY S{I+ qM StrB rrov(m lrov [u rnI ryTora @ttl llov Mm Ntlt miE ,/ clBff rcNolE EE(mrd - dErY ord uP - Etm*m wa:E leT a' &Lotssxl mp -t 2 tr8tnffsr{i91p tuffi 6al,f,D fAtxI cffcl11NEtnwto aur [ECnr& PWt Fn NC trN Pnfw" w,/ uflr coveo 2!Y &ttLt BAi{ NS &EI sNM ifGP'AdE nrorc &nct E&loi aMI cruto {ohr nrwiE EroEl u0 t0t EIN&I T& ca8& lv& w( ru {,!6 u[or rur 0{l! [@ ucil uscriEct suTcH i^B;: ":...,:-:-' ARCHITECTURE CEtrNC FIff PETWE Page 179 of 303 FO e.FZoo a-F Lo U0oO Io F:)o a UFa a) oz-OU = LiiFoz =r-, o ft;.s a"l z)c) () =-O = 6.9 l!f IL3-J 0 .=Cf c 0) C) G E €No) Jl 5.9 L! !o = =Ll C o)o(5 E.=Cf c o)oo:o 8/gn'ln oulsrxf lleM poleu rnoH I t-- Z t.f o Z o m UJ t l F o IJ : I o (r .t: i tllL ' < li z Page 180 of 303 Page 181 of 303 Page 182 of 303 Page 183 of 303 Complaint Number: 2025-13 Contractors' Licensing Board 2800 North Horseshoe Dr. Naples, FL 34104 Complainant: Any person who believes that a Contractor holding a Collier County Certificate of competency has violated Collier County Ordinance 22-201, as amended, may submit a sworn complaint to the Contractor Licensing supervisor, or his / her designee. The complaint shall be in substantially the form prescribed by the Contractor Licensing Supervisor. The complaining party shall state with particularity which section(s) of this Ordinance he or she believes has been violated by the contractor and the essential facts in support thereof. Complaint: Please print or type and return signed copies of the complaint. Date: Septem her 2, 2025 Against: Contractor's Name: Rene A. Aviles Phone: 239 810-4184 Business Name: FULL CONSTRUCTION SERVICES INC License(s) Held: General Contractor (CGC1513065) Collier County Competency number: 32676 Contractor's Business Address: 2617 SHELBY PARKWAY, CAPE CORAL FL 33904 Filed By: Name: Collier County Contractors' Licensing: Larry Zydek Address: 2800 N. Horseshoe Dr., Naples, FL 34104 Business Phone: 239 821-7553 Address where work done: 209 Mentor DR City: Naples County: Collier Date of contract: December 30, 2022 1 Page 184 of 303 Date job started: On or after January 8, 2023 Date job completed or new home occupied: N/A Were there plans and specifications: Yes Is there a written contract: Yes If yes, amount of Contract: $59,148.00 Has Contractor been paid in full: No If not, what amount: Approx. $44,500 Was a permit obtained: Yes Was a permit required: Yes Permit number if known: PRSPL20230414398 Have you communicated by letter with the licensee: Yes Date: August 14, 2025 Do you have a reply: Yes Please attach to this form all copies of the purchase agreement, building contract, home improvement contract, copies of receipts and/or cancelled checks available and any additional evidence to substantiate your allegations. List any subsections of Collier County Ordinance number 22-201, which, in your opinion, have been violated by the contractor, which is the subject of this complaint, (list subsection number): A. Collier County Ordinance 22-201(1)(2) Willfully violating the applicable building codes or laws of the state, city or Collier County. Please state the facts which you believe substantiate your charge of misconduct against the subject contractor. List facts separately for each subsection number above: A. Collier County Ordinance 22-201(1)(2) Willfully violating the applicable building codes or laws of the state, city or Collier County. I . The respondent, RENE A. A VILES, failed to correct known documented deficiencies associated with a failed building inspection after receiving multiple formal notices and reasonable opportunity to comply. 2. MR. RENE A. A VILES is in violation of The Code of Laws and Ordinances of Collier County, Florida [Section 22-20 I ( I )(2)], which states, in pertinent part, that it is misconduct for a holder of a Collier County Certificate of Competency to willfully violate the applicable building codes or laws of the state, city or Collier County. and as defined in this ordinance or as restricted by the Contractors' Licensing Board. 2 Page 185 of 303 Licensing Compliance Investigator -Code Enforcement State of hor' ,· de-County of / C)/ /, '--t,.r . -/ The foregoing instrument was acknowledg~efore me by means of tf1>hysical presence or D online notarization on this 1JL day of~ 20 li, by ~..a:,~~'i:::J:,!.~--------------- Su pe on(s) otary Public must check applicable box: -are personally known to me D has produced a current driver license D has produced ____________ as identification. (Notary Seal) RYAN CATHEY Corm1isslon t HH 521188 Expires April 28, 2028 Notary s;gnatue, ~/j~b-,L_ _____________ _ 3 Page 186 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net Received by: ______________________________________ Date: ____________________ August 14, 2025 Rene A. Aviles FULL CONSTRUCTION SERVICES INC 2617 Shelby Pkwy Cape Coral, FL 33904 RE: Case # CEMIS20250005737 – 209 Mentor DR, Naples FL VIOLATION: Willful Code Violation – EXPIRED PERMIT and FAILED INSPECTIONS. Permit PRSPL20230414398. Date of Violation: August 14,2025. Dear Rene A. Aviles, A complaint has been filed against you. A hearing of this complaint will be held by the Contractors’ Licensing Board on Wednesday, September 17, 2025, at 9:00 AM in the Board of County Commissioner’s Room, Third Floor, Administration Building (W. Harmon Turner Bldg.), at 3301 East Tamiami Trail, Naples, Florida 34112. Your presence before the Collier County Contractors’ Licensing Board is REQUIRED. The packet concerning your case marked composite exhibit “A” will be delivered to the Contractors’ Licensing Board members one week before the hearing. If you wish to receive a copy of this packet, please notify the Contractor Licensing Customer Service Office. If you wish to prepare a defense packet and have it delivered with composite exhibit “A”, you must make fifteen copies and have them in our office by 8:00 AM on Wednesday, one week before the hearing. In your packet, you may give a summary of events. At this meeting, you may present evidence and be represented by an attorney of your choice. Page 187 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net In the event that the Contractors’ Licensing Board finds you in violation of Sec. 22-201.1 of the Collier County, FL Code of Laws and Ordinances: Sec. 22-201.1 – MISCONDUCT – State Certified Contractors The following actions by state certified contractors shall constitute misconduct and grounds for discipline pursuant to section 22-202 of this article. (2) Willfully violating the applicable building codes or laws of the state, city, or Collier County. The range of disciplinary sanctions which may be imposed are (1) denial of Collier County/City building permits or require the issuance of permits with specific conditions; (2) recommendation for suspension, revocation, or restriction of your certificate of competency, or a fine to be levied by the Construction Industry Licensing Board. Respectfully, Larry Zydek Investigator Collier County Contractor Licensing 239 821-7553 Initials ______ Page 188 of 303 1 Larry Zydek From:Larry Zydek Sent:Thursday, August 14, 2025 4:09 PM To:Fullconstructionservices@yahoo.com Cc:Larry Zydek Subject:Notice of Hearing - Willful Code Violation **PLEASE READ AND RESPOND** Attachments:Notice of Hearing.pdf Hello Rene A. Aviles (Qualifier), FULL CONSTRUCTION SERVICES INC License# CGC1513065 Issuance# 32676 The Collier County Building Department has determined a WILLFUL CODE VIOLATION exists regarding case CEMIS20250005737. Your appearance is REQUIRED at the Contractor Licensing Board hearing to be conducted on Wednesday, September 17, 2025, at 9:00am. Please refer to the attached NOTICE OF HEARING for details. Please respond to this email to confirm receipt. If there are any questions please contact me. Respectfully, Larry Zydek Code Enforcement Officer I Code Enforcement Mobile:239-821-7553 CONTRACTOR LICENSING - 2800 N Horseshoe City of Naples, FLORIDA 34104 Larry.Zydek@colliercountyfl.gov Under Florida Law, e-mail addresses are public records. If you do not want your e-mail address released in response to a public records request, do not send electronic mail to this entity. Instead, contact this office by telephone or in writing. Page 189 of 303 1 Larry Zydek From:Rene Aviles <fullconstructionservices@yahoo.com> Sent:Saturday, August 16, 2025 2:06 PM To:Larry Zydek Subject:Re: Notice of Hearing - Willful Code Violation **PLEASE READ AND RESPOND** EXTERNAL EMAIL: This email is from an external source. Confirm this is a trusted sender and use extreme caution when opening attachments or clicking links. Hello Larry I got it your notice of Hearing Thks Rene On Thursday, August 14, 2025 at 04:08:59 PM EDT, Larry Zydek <larry.zydek@colliercountyfl.gov> wrote: Hello Rene A. Aviles (Qualifier), FULL CONSTRUCTION SERVICES INC License# CGC1513065 Issuance# 32676 The Collier County Building Department has determined a WILLFUL CODE VIOLATION exists regarding case CEMIS20250005737. Your appearance is REQUIRED at the Contractor Licensing Board hearing to be conducted on Wednesday, September 17, 2025, at 9:00am. Please refer to the attached NOTICE OF HEARING for details. Please respond to this email to confirm receipt. If there are any questions please contact me. Page 190 of 303 2 Respectfully, Larry Zydek Code Enforcement Officer I Code Enforcement Mobile:239-821-7553 CONTRACTOR LICENSING - 2800 N Horseshoe City of Naples, FLORIDA 34104 Larry.Zydek@colliercountyfl.gov Under Florida Law, e-mail addresses are public records. If you do not want your e-mail address released in response to a public records request, do not send electronic mail to this entity. Instead, contact this office by telephone or in writing. Page 191 of 303 1 Larry Zydek From:Rene Aviles <fullconstructionservices@yahoo.com> Sent:Tuesday, July 15, 2025 1:16 PM To:Larry Zydek Subject:Re: Code Violation - Permit Requirement ***PLEASE READ and RESPOND*** Attachments:Request Permit Extension .pdf EXTERNAL EMAIL: This email is from an external source. Confirm this is a trusted sender and use extreme caution when opening attachments or clicking links. Hello Larry, Thanks for call me today and let me know Sorry for the delay on this permit I had a couples health problem, but my supervisor is working with Mr. Boulter Today finally I requested the extension (see attached form), and I called to the office, they said take between 24 and 48 hours to active the permit As soon as get ready I'll require the pendent inspection and close up this permit I'll let you know the status steps Thks so much for your assistance Rene A. Aviles Full Construction Services, Inc. CPC1457891 Commercial Pool/SPA Contractor License p. 239.810.4184 e. fullconstructionservices@yahoo.com On Tuesday, July 15, 2025 at 10:38:42 AM EDT, Larry Zydek <larry.zydek@colliercountyfl.gov> wrote: Hello Rene A. Aviles (Qualifier), FULL CONSTRUCTION SERVICES INC Page 192 of 303 $ 695,000 $ 133,000 $ 280,000 $ 209,000 $ 144,500 $ 111,300 $ 101,000 $ 87,000 $ 89,000 $ 339,315 $ 153,431 $ 492,746 $ 492,746 $ 25,000 $ 467,746 $ 25,000 $ 442,746 $ 4,390.30 $ 255.52 $ 4,645.82 Collier County Proper ty AppraiserProperty Summar y Parcel ID 82538000008 Site Address*Disclaimer 209 MENTOR DR Site City NAPLES Site Zone*Note 34110 Name / Address BOULTER, STUART TINA LOUISE KOBAN 209 MENTOR DR City NAPLES State FL Zip 34110-1354 Map No.Strap No.Section Township Range Acres *Estimated 3A24 719200 2063A24 24 48 25 0.25 Legal WILLOUGHBY ACRES LOT 206 Millage Area 95 Millage Rates *Calculations Sub./Condo 719200 - WILLOUGHBY ACRES School Other Total Use Code 1 - SINGLE FAMILY RESIDENTIAL 4.3132 5.3593 9.6725 Latest Sales Histor y (Not all Sales are listed due to Confidentiality) Date Book-Page Amount 09/16/22 6175-2900 09/22/15 5205-3415 04/15/08 4349-3136 03/01/04 3510-432 12/06/01 2937-2800 12/31/98 2498-954 07/02/98 2436-2443 05/17/96 2184-1744 10/01/90 1563-2297 2024 Certified Tax Roll (Subject to Change) Land Value (+) Improved Value (=) Market Value (=) Assessed Value (-) Homestead (=) School Taxable Value (-) Additional Homestead (=) Taxable Value Ad Valorem Taxes (+) Non-Ad Valorem Taxes (=) Total Taxes Values are as of Januar y 1st each year. If all values are 0, this parcel was createdafter the Final Tax Roll. Disclaimer: The actual total property taxes may vary due to changes in millagerates set by taxing authorities, the addition of non-ad valorem assessments, andspecial assessments. For the most accurate and up-to-date tax information,please visit the Collier County Tax Collector's office to see the final Tax bills. 5/14/25, 1:25 PM Collier County Property Appraiser https://www.collierappraiser.com 1/1Page 193 of 303 Parcel Number:82538000008 Status:Active Legal Description:WILLOUGHBY ACRES LOT 206 Acres:0.25 Bald Eagle Nest Buffer?:No Block: CCSL?:No FLN:82538000008 Improvement Value:$153,431.00 Land Value:$339,315.00 Map Number:3A24 Range:25 Section:24 SQ Last Updated:07/30/2025 Taxes:$4,839.21 Township:48 Use Code:1 Property Review Parcel Number: 82538000008 Property Details Addresses Street #Pre-Direction Street Name Direction Unit #Status 209 Mentor DR Active 209 Mentor DR Historic 209 Mentor DR Inactive Contacts Type Description Property Owner BOULTER, STUART TINA LOUISE KOBAN, Address:209 MENTOR DR Historic Owner WARDEIN, NICHOLAS & RUTH, Address:209 MENTOR DR Historic Owner PALMATEER, SCOTT ANGELINA PALMATEER, Address:209 MENTOR DR Historic Owner PALMATEER, SCOTT ANGELINA PALMATEER, Address:209 MENTOR DR Historic Owner PALMATEER, SCOTT, Address:209 MENTOR DR Historic Owner PALMATEER, SCOTT, Address:209 MENTOR DR Historic Owner PALMATEER, SCOTT, Address:209 MENTOR DR Code Enforcement Complaints Case Number Type Status Date Entered CEMIS20250005737 Misconduct Investigation 05/12/2025 Description: Expired permit with failed / incomplete inspections: PRSPL20230414398 9/10/25, 8:11 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO82538000008 1/5Page 194 of 303 Case Number Type Status Date Entered CEAC20240010885 Animal Control Closed 11/12/2024 Description: Collier County Sheriff's Office stated two large dogs have been confined and the caller Stuart Boulter 732-979-8634 needs them picked up CEAC20240010868 Animal Control Closed 11/12/2024 Description: 2 found dogs, no collar. CCSO provided address but disconnected call without providing name or contact information for reporting party. CEROW20240000589 Right of Way Closed 01/22/2024 Description: Pool being constructed. Water is flowing into a ditch. The pipes are clogged causing flooding onto callers property. CEV20120005211 Vehicles Closed 04/05/2012 Description: 6:30pm till morning 6am box trailer there and all weekends CEV20120003630 Vehicles Closed 03/09/2012 Description: Home owner continually parks his utility trailer in the front of his home on a daily basis. CECV20120003247 Code Violation Closed 03/02/2012 Description: referal case from code- CEROW20120003247- no ROW permit - B&W Paving CEROW20120002881 Right of Way Closed 02/24/2012 Description: NO RIGHT OF WAY PERMIT (CALLER CHECKED WITH ROW-JEN)- POURING BLACK PAVEMENT ADDING TO THEIR DRIVEWAY. CESD20080014888 Site Development Closed 10/03/2008 Description: Screen Lani enclosed at notheast corner of back of house. This area was screen and is now stucco over wood with two sliding doors which are also new. Wood porch has built on both the back and front of house. Also a wood sidewalk has been built in the front of the house. Approximately 6 to 8 weeks ago, the family moved out of the house and the entire inside out the house was gutted and redone. Electrical work and not sure what else work was done at night. Sugguest a floor plan of the home prior to this be pulled and compared with what is there now. Truck and trailer is parked on front side yard everynight. 2007020359 Legacy - Environmental Closed 02/13/2007 Description: [CC_DESC:GRASS IS HIGHER THAN 18 INCHES.][CC_DISP:ABATED] 2002080407 Legacy - Environmental Closed 08/13/2002 Description: [CC_DESC:WEEDS IN EXCESS 18 " PR][CC_DISP:ABATED] 2002060821 Legacy - Environmental Closed 06/21/2002 Description: [CC_DESC:MISC TRASH AND WEEDS ARE IN EXCESS OF 18" PR] [CC_DISP:ABATED] 80410037 Legacy - Environmental Closed 04/10/1998 Description: [CC_DESC:COUCH IN R.O.W.][CC_DISP:CASE CLOSED] 50522038 Vehicles Closed 05/22/1995 Description: [CC_DESC:TRUCK NO LIC PLATE - PARKED NEXT TO D/W ON GRASS] [CC_DISP:CASE CLOSED] 41128010 Legacy - Zoning Closed 11/28/1994 Description: [CC_DESC:SEMI - TRUCK CAB PARKED IN STREET.][CC_DISP:CASE CLOSED] 41128011 Legacy - Zoning Closed 11/28/1994 9/10/25, 8:11 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO82538000008 2/5Page 195 of 303 Case Number Type Status Date Entered Description: [CC_DESC:CK BLUE/GREY P/U TRUCK, PARKED ALONG TIME NOT RUNNING. POSSIBLE EXPIRED TAG.][CC_DISP:CASE CLOSED] 41128012 Legacy - Zoning Closed 11/28/1994 Description: [CC_DESC:BOAT PARKED IN SIDE YD.][CC_DISP:CASE CLOSED] License Applications No records were found. Permit Applications Application Number Type Work Class Status Date Issued PRFW20240519759 Fence/Wall Alteration/Remodel Finaled 06/06/2024 Permits: Description: Installing a side fence/ gate on both sides of the house. Total length of fence and gate will be 10' 8" (on the right of the house) and 9'3" (on the left). Both fences (freedom emblem 6ft H x 5ft W white Vinyl fence gate kit) will be white vinyl 6' in hight. Each gate will be 6' in hight and 5' in width. both gates will be self laching with the latch on both gates at least 54" from the bottom of the gate, both gates will open away from the pool. ( POOL PRSPL20230414398 ) 209 Mentor DR PRSD20230728848 Shutters/Doors/Windows Alteration/Remodel Finaled 07/20/2023 Permits: Description: REPLACE 3 WINDOWS SZ4SZ WITH IMPACT 209 Mentor DR, Naples Lot 206 PRSPL20230414398 Pool New Construction Inspections Commenced 01/08/2024 Permits: Description: PROPOSED A NEW IN-GROUND CONCRETE POOL 209 Mentor DR, Naples PRBD20210314062 Building Alteration/Remodel Finaled 04/12/2021 Permits: Description: Replace garage door size for size with Florida Building Commission approved, impact rated door 209 MENTOR DR LOT 206 PRBD20190728350 Building Addition Finaled 10/11/2019 9/10/25, 8:11 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO82538000008 3/5Page 196 of 303 Application Number Type Work Class Status Date Issued Permits: Description: CONSTRUCTION OF ADDITION TO EXISTING RESIDENCE INCLUDING 2 BEDROOMS AND ONE BATHROOM - PROPOSED ADDITION IS 24'X36'-6" REV 1 - SERVICE CHANGE 209 Mentor DR, Naples LOT 206 PRBD20120510834 Building Alteration/Remodel Finaled 05/22/2012 Permits: Description: RE-ROOF SHINGLE TO SHINGLE 209 MENTOR DR LOT 206 SUB-WILLOUGHBY ACRES Mechanical, Electrical, Plumbing, Gas & Fire Permit Applications No records were found. Right of Way, Sign & Well Permit Applications No records were found. Planning Applications No records were found. Special Events, Zoning Certificates, Temporary Use, Short-Term Vacation Rental Registration, RV & Garage Sale Permit Applications No records were found. Environmental Permit Applications No records were found. 9/10/25, 8:11 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO82538000008 4/5Page 197 of 303 9/10/25, 8:11 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO82538000008 5/5Page 198 of 303 Report Title: Date: Code Case Details 9/10/2025 10:01:51 AM Case Number:CEMIS20250005737 Case Information CEMIS20250005737Case Number: Case Type: Priority: Misconduct Normal Inspector: Jurisdiction: Origin: Larry.Zydek Collier County Complaint Detail Description:Expired permit with failed / incomplete inspections: PRSPL20230414398 Location Comments:209 Mentor Dr InvestigationStatus: Date & Time Entered: Entered By: 5/12/2025 2:40:30 PM ryancathey Case Disposition:Case Pending Address 209 Mentor DR, Naples Property 82538000008 Address Location Primary Contractor FULL CONSTRUCTION SERVICES INC Complainant Collier County Building Dept. Address:2800 N Horseshoe Dr. Property Owner BOULTER, STUART TINA LOUISE KOBAN Qualifier RENE A. AVILES Contacts 1Business Management & Budget Office Page 199 of 303 Execution Date 9/10/2025 10:01:51 AMCode Case Details Investigations Desc Assigned Required Completed Outcome Comments Preliminary Investigation Larry.Zydek 5/12/2025 5/14/2025 Needs Investigatio n Expired permit PRSPL20230414398 - needs investigation. CE Staff Review ryancathey 5/12/2025 5/12/2025 Complete Stuart Boulter - 732-979-8634 - 209 Mentor Dr. Expired permit with failed inspections (PRSPL20230414398): Last contact was approximately December 2024 with no responose from contractor. CE Phone Call Larry.Zydek 5/14/2025 5/14/2025 Complete Called Full Construction Services Inc / Qualifier Rene A. Aviles (239 810-4184) to advise of expired permit / failed inspections. He stated he would resolve the issue. Cont. Investigation Larry.Zydek 5/14/2025 5/14/2025 Complete Sent 30 Day Email to Rene A. Aviles (fullconstructionservices@yahoo.com) with information on the expired permit. CE Phone Call Larry.Zydek 6/16/2025 6/16/2025 Complete Called Full Construction Services Inc / Qualifier Rene A. Aviles (239 810-4184) to again advise of expired permit / failed inspections. Left message. Cont. Investigation Larry.Zydek 6/16/2025 6/16/2025 Complete 2nd 30 Day Email sent to qualifier. CE Phone Call Larry.Zydek 7/15/2025 7/15/2025 Complete Called Full Construction Services Inc / Qualifier Rene A. Aviles (239 810-4184) to again advise of expired permit / failed inspections. No answer, left message. CE Phone Call Larry.Zydek 7/15/2025 7/15/2025 Complete Called Stuart Boulter (732 979-8634). Stuart told me he has had no contact with Rene Aviles or Full Construction Services Inc. until earlier this morning when Rene apparently called him and stated he would resolve the permit and inspection issues within 48 hours. Stuart also stated one of the employees was coming to the home this morning to address a leak from the pool heater. CE Phone Call Larry.Zydek 7/15/2025 7/15/2025 Complete Called Full Construction Services / Rene Aviles again (239 810-4184). No answer, left message. Cont. Investigation Larry.Zydek 7/15/2025 7/15/2025 Complete Sent third and final 30 Day email to Full Construction Services (fullconstructionservices@yahoo.com). Cont. Investigation Larry.Zydek 7/15/2025 7/15/2025 Complete Rene Aviles responded to the 3rd 30 Day email stating he has submitted a request to extend the permit and resolve the issue. Cont. Investigation Larry.Zydek 8/14/2025 8/14/2025 Complete I spoke with Stuart Boulter, who confirmed there has been no contact with Full Construction Services or Rene Aviles. Sent email to Stuart (kovanbounter@gmail.com) to obtain copy of contract and payments. Cont. Investigation Larry.Zydek 8/14/2025 8/14/2025 Complete Correct email for Stuart Boulter is kobanboulter@gmail.com 2Business Management & Budget Office Page 200 of 303 Execution Date 9/10/2025 10:01:51 AMCode Case Details Desc Assigned Required Completed Outcome Comments Cont. Investigation Larry.Zydek 8/14/2025 8/14/2025 Complete Sent Notice of Hearing to Rene Aviles via email. Cont. Investigation Larry.Zydek 8/18/2025 8/18/2025 Complete Rene Aviles responded via email that he has received the hearing notice. Cont. Investigation Larry.Zydek 8/28/2025 8/28/2025 Complete Permit PRSPL20230414398 has been extended and now expired 08-11-2027. Called Rene Aviles (239 810-4184) to inquire about inspections. Left message. Investigation Larry.Zydek 9/10/2025 Pending ADDRESS: 209 Mentor DR PROPERTY OWNER: Stuart Boulter COMPLAINANT: Stuart Boulter COMPLAINT: Expired permit with failed inspections CONTRACTOR: FULL CONSTRUCTION SERVICES INC LICENSE#: CGC1513065 PERMIT#: PRSPL20230414398 STATUS: EXPIRED AS OF: 09-25-2024 Violations Violation Description Status Entered Corrected Amount Comments Hearings Title Reason Result Compliance Fine/Day Condition 3Business Management & Budget Office Page 201 of 303 Page 202 of 303 Page 203 of 303 Page 204 of 303 Page 205 of 303 Page 206 of 303 Page 207 of 303 Page 208 of 303 Page 209 of 303 Document Number FEI/EIN Number Date Filed State Status Last Event Event Date Filed Event Effective Date Department of State / Division of Corporations / Search Records / Search by Entity Name / Detail by Entity Name Florida Profit Corporation FULL CONSTRUCTION SERVICES, INC. Filing Information P07000104700 42-1741151 09/19/2007 FL ACTIVE AMENDMENT 10/06/2014 NONE Principal Address 2617 SHELBY PRWY. CAPE CORAL, FL 33904 Changed: 03/04/2019 Mailing Address 2617 SHELBY PRWY. CAPE CORAL, FL 33904 Changed: 03/04/2019 Registered Agent Name & Address AVILES, RENE 2617 SHELBY PRWY. CAPE CORAL, FL 33904 Name Changed: 01/22/2021 Address Changed: 01/31/2020 Officer/Director Detail Name & Address Title VP D i v i s i o n o f C o r p o r at i o n sFlorida Department of State 9/10/25, 8:14 AM Detail by Entity Name https://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder=FULLCON…1/3Page 210 of 303 AVILES, NIVIA E. 2617 SHELBY PRWY. CAPE CORAL, FL 33904 Title P, GCM AVILES, RENE 2617 SHELBY PKWY CAPE CORAL, FL 33904 Title D AVILES, VICTOR 2617 SHELBY PRWY. CAPE CORAL, FL 33904 Annual Reports Report Year Filed Date 2023 01/30/2023 2024 01/31/2024 2025 02/05/2025 Document Images 02/05/2025 -- ANNUAL REPORT View image in PDF format 01/31/2024 -- ANNUAL REPORT View image in PDF format 01/30/2023 -- ANNUAL REPORT View image in PDF format 02/01/2022 -- ANNUAL REPORT View image in PDF format 01/22/2021 -- ANNUAL REPORT View image in PDF format 06/13/2020 -- AMENDED ANNUAL REPORT View image in PDF format 01/31/2020 -- ANNUAL REPORT View image in PDF format 03/04/2019 -- ANNUAL REPORT View image in PDF format 01/12/2018 -- ANNUAL REPORT View image in PDF format 01/12/2017 -- ANNUAL REPORT View image in PDF format 03/28/2016 -- ANNUAL REPORT View image in PDF format 02/23/2015 -- ANNUAL REPORT View image in PDF format 10/06/2014 -- Amendment View image in PDF format 02/28/2014 -- ANNUAL REPORT View image in PDF format 03/23/2013 -- ANNUAL REPORT View image in PDF format 03/12/2012 -- ANNUAL REPORT View image in PDF format 02/28/2011 -- ANNUAL REPORT View image in PDF format 11/30/2010 -- Amendment View image in PDF format 10/29/2010 -- Amendment View image in PDF format 02/28/2010 -- ANNUAL REPORT View image in PDF format 03/18/2009 -- ANNUAL REPORT View image in PDF format 03/07/2008 -- ANNUAL REPORT View image in PDF format 09/19/2007 -- Domestic Profit View image in PDF format 9/10/25, 8:14 AM Detail by Entity Name https://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder=FULLCON…2/3Page 211 of 303 Florida Department of State, Division of Corporations 9/10/25, 8:14 AM Detail by Entity Name https://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder=FULLCON…3/3Page 212 of 303 HOME CONTACT US MY ACCOUNT T H E O F F I C I A L S I T E O F T H E F L O R I D A D E P A R T M E N T O F B U S I N E S S & P R O F E S S I O N A L R E G U L A T I O N ONLINE SERVICES Apply for a License Verify a Licensee View Food & Lodging Inspections File a Complaint Continuing Education Course Search View Application Status Find Exam Information Unlicensed Activity Search AB&T Delinquent Invoice & Activity List Search LICENSEE DETAILS 8:17:10 AM 9/10/2025 Licensee Information Name:AVILES, RENE A (Primary Name) FULL CONSTRUCTION SERVICES INC (DBA Name) Main Address:2617 SHELBY PARKWAY CAPE CORAL Florida 33904 County:LEE License Location:2617 SHELBY PKWY CAPE CORAL FL 33904 County:LEE License Information License Type:Certified General Contractor Rank:Cert General License Number:CGC1513065 Status:Current,Active Licensure Date:02/27/2007 Expires:08/31/2026 Special Qualifications Qualification Effective Construction Business 02/27/2007 Alternate Names View Related License Information View License Complaint 2601 Blair Stone Road, Tallahassee FL 32399 :: Email: Customer Contact Center :: Customer Contact Center: 850.487.1395 The State of Florida is an AA/EEO employer. Copyright ©2023 Department of Business and Professional Regulation - State of Florida. Privacy Statement Under Florida law, email addresses are public records. If you do not want your email address released in response to a public-records request, do not send electronic mail to this entity. Instead, contact the office by phone or by traditional mail. If you have any questions, please contact 9/10/25, 8:18 AM DBPR - AVILES, RENE A; Doing Business As: FULL CONSTRUCTION SERVICES INC, Certified General Contractor https://www.myfloridalicense.com/LicenseDetail.asp?SID=&id=1F0BAE19075868BD4C043BCE8F0A8D10 1/2Page 213 of 303 850.487.1395. *Pursuant to Section 455.275(1), Florida Statutes, effective October 1, 2012, licensees licensed under Chapter 455, F.S. must provide the Department with an email address if they have one. The emails provided may be used for official communication with the licensee. However email addresses are public record. If you do not wish to supply a personal address, please provide the Department with an email address which can be made available to the public. Please see our Chapter 455 page to determine if you are affected by this change. 9/10/25, 8:18 AM DBPR - AVILES, RENE A; Doing Business As: FULL CONSTRUCTION SERVICES INC, Certified General Contractor https://www.myfloridalicense.com/LicenseDetail.asp?SID=&id=1F0BAE19075868BD4C043BCE8F0A8D10 2/2Page 214 of 303 (1) (2) (3) Sec. 22-162. - Denitions and contractor qualications. The following words, terms and phrases, when used in this article, shall have the meanings ascribed to them in this section, except where the context clearly indicates a different meaning: Business organization means any partnership, corporation, business trust, joint venture, or other legal entity which engages or offers to engage in the business of contracting or acts as a contractor as defined in this section. Contracting means, except as exempted in this part, engaging in business as a contractor and includes, but is not limited to, performance of any of the acts as set forth in subsection (3) which define types of contractors. The attempted sale of contracting services and the negotiation or bid for a contract on these services also constitutes contracting. If the services offered require licensure or agent qualification, the offering, negotiation for a bid, or attempted sale of these services requires the corresponding licensure. However, the term "contracting" shall not extend to an individual, partnership, corporation, trust, or other legal entity that offers to sell or sells completed residences on property on which the individual or business entity has any legal or equitable interest, if the services of a qualified contractor certified or registered pursuant to the requirements of this chapter have been or will be retained for the purpose of constructing such residences. Contractor means the person who is qualified for and responsible for the entire project contracted for and, except for those herein exempted, the person who, for compensation, undertakes to, or submits a bid to, or does himself or by others, any or all of the following: construct, repair, alter, remodel, add to, demolish, subtract from, or improve any building or structure, including related improvements to real estate, for others, or for resale to others, as hereinafter defined in this section. General contractor requires 48 months experience with a passing grade on an approved test and a business and law test and means a contractor whose services are unlimited as to the type of work which he/she may do, except as provided in this article or in the Florida Statutes. (See also the definition of subcontractors.) Building contractor requires 48 months experience with a passing grade on an approved test and a business and law test and means a contractor whose services are limited to construction of commercial buildings and single-dwelling or multiple-dwelling residential buildings, which commercial or residential buildings do not exceed three stories in height, and accessory use structures in connection therewith or a contractor whose services are limited to remodeling, repair, or improvement of any size building if the services do not affect the structural members of the building. (See also the definition of subcontractor.) Residential contractor requires 48 months experience with a passing grade on an approved test and a business and law test and means a contractor whose services are limited to construction, remodeling, repair, or improvement of one-family, two-family, or three-family 6/11/25, 9:23 AM Collier County, FL Code of Ordinances about:blank 1/17Page 215 of 303 Application Number:PRSPL20230414398 Application Type:Pool Application Status:Inspections Commenced Property Owner's Full Name:BOULTER, STUART TINA LOUISE KOBAN Category of Work:New Construction Occupancy Code:Residential, One and Two Family New or Guest House Description of Work:PROPOSED A NEW IN-GROUND CONCRETE POOL 209 Mentor DR, Naples Application Date:04/06/2023 Issued Date:01/08/2024 Expiration Date:09/25/2024 1-2 Family or Comm:1-2 Family Locations:Property 82538000008 Address 209 Mentor DR, Naples Applicant:Rene A. Aviles, Address:2617 Shelby parkway., Phone:(239) 810-4184 Property Owner:BOULTER, STUART TINA LOUISE KOBAN, Address:209 MENTOR DR Qualifier:RENE A. AVILES, Address:2617 SHELBY PARKWAY, Phone:(239) 810- 4184, Licensee # Q29712 License Status SubContractor: Electrical:E & SON ELECTRIC CORP, Address:157 SE 27TH ST, Phone:(239) 541- 2286, State Reg #'s ES12000913, Licensee # LCC20120001340 License Status SubContractor: Pool:FULL CONTRUCTION SERVICES INC, Address:2617 SHELBY PKWY, Phone:(239) 810-4184, State Reg #'s CPC1457891, Licensee # LCC20240000013 License Status Primary Contractor:FULL CONSTRUCTION SERVICES INC, Address:2617 SHELBY PARKWAY, Phone:(239) 810-4184, State Reg #'s CGC1513065, Licensee # C32676 License Status Permit Type:Pool Permit Status:Inspections Commenced Permit Application Status PRSPL20230414398 Summary Locations Contacts Permits (Click to See Reviews) Permit Number: PRSPL2023041439801 1 Initial Submittal Status: Returned for Correction Review Type Outcome Est. Completion Date Completed 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 1/12Page 216 of 303 Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:07/26/2023 Comments:-Per LDC Section 6.05.03, please provide a Type I or Type II stormwater plan that identifies the total lot area, and total impervious (existing plus proposed). If 40% or less of the total lot is impervious area, then a Type I stormwater plan is required and must verify directional flow (flow arrows) of stormwater generated from the proposed improvements will not impact adjacent properties. If more than 40% impervious area, a Type II stormwater plan signed and sealed by a registered professional engineer is required for the excess impervious area. Please note that per LDC Section 6.05.03, pools are considered impervious area. Please see link below for stormwater requirements. http://www.colliercountyfl.gov/home/showdocu ment?id=72831 Final Type Review Complete 07/06/2023 06/16/2023 Reviewer:LEGACY: BerlYves Mercier ((239) 252-2398) Send Email Engineering Review Rejected 06/21/2023 06/15/2023 Reviewer:Didier Diaz ((239) 252-2918) Send Email Corrections: Plumbing and Handicap Review Approved 06/21/2023 06/13/2023 Reviewer:Tobias Hytonen ((239) 252-2659) Send Email Zoning Review Approved 06/21/2023 06/12/2023 Reviewer:LEGACY: Mark Morton ((239) 252-2361) Send Email Floodplain Review Approved 06/21/2023 06/02/2023 Reviewer:Milena Martinez ((239) 252-1448) Send Email 2 Re-Submittal Status: Returned for Correction Review Type Outcome Est. Completion Date Completed Final Type Review Complete 09/07/2023 08/14/2023 Reviewer:Angel Tarpley ((239) 252-5625) Send Email Engineering Review Rejected 08/23/2023 08/14/2023 Reviewer:Didier Diaz ((239) 252-2918) Send Email 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 2/12Page 217 of 303 Correction 1:Miscellaneous Corrections Status:Withdrawn Date Status Changed:08/14/2023 Comments:-Per LDC Section 6.05.03, please provide a Type I or Type II stormwater plan that identifies the total lot area, and total impervious (existing plus proposed). If 40% or less of the total lot is impervious area, then a Type I stormwater plan is required and must verify directional flow (flow arrows) of stormwater generated from the proposed improvements will not impact adjacent properties. If more than 40% impervious area, a Type II stormwater plan signed and sealed by a registered professional engineer is required for the excess impervious area. Please note that per LDC Section 6.05.03, pools are considered impervious area. Please see link below for stormwater requirements. http://www.colliercountyfl.gov/home/showdocu ment?id=72831 Correction 2:Miscellaneous Corrections Status:Carried Forward Date Status Changed:12/20/2023 Comments:-Stormwater Plan Worksheet shows 80 ft as the lot with and 168 ft as the lot depth (Site Plan indicate that the right number would be 136.10 ft) so the total Square footage is 10,888 sf (not 13,120 sf as shown under your calculations), then the total Impervious Area would be 43.46 sf which is over the 40% allowed for an RSF-3 zoning. Per LDC Section 6.05.03 please provide a Type II Stormwater Plan. Corrections: 3 Re-Submittal Status: Complete Review Type Outcome Est. Completion Date Completed Final Type Review Complete 02/06/2024 12/21/2023 Reviewer:Marianella Rothschild ((239) 252-2400) Send Email Engineering Review Approved 01/23/2024 12/21/2023 Reviewer:Didier Diaz ((239) 252-2918) Send Email 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 3/12Page 218 of 303 Correction 1:Miscellaneous Corrections Status:Withdrawn Date Status Changed:12/21/2023 Comments:-Stormwater Plan Worksheet shows 80 ft as the lot with and 168 ft as the lot depth (Site Plan indicate that the right number would be 136.10 ft) so the total Square footage is 10,888 sf (not 13,120 sf as shown under your calculations), then the total Impervious Area would be 43.46 sf which is over the 40% allowed for an RSF-3 zoning. Per LDC Section 6.05.03 please provide a Type II Stormwater Plan. Correction 2:Miscellaneous Corrections Status:Resolved Date Status Changed:12/21/2023 Comments: Corrections: Fees Paid Fees Amount Paid Owing Date Paid Pool or Spa - New Residential - Application $50.00 $50.00 Paid 05/23/2023 Zoning Review - Application $50.00 $50.00 Paid 05/23/2023 Inspection Fee $405.00 $405.00 Paid 12/23/2023 Site Engineering $150.00 $150.00 Paid 12/23/2023 BCAI $6.83 $6.83 Paid 12/23/2023 DBPR Surcharge $4.55 $4.55 Paid 12/23/2023 Outstanding Fees Amount Paid Owing Date Paid Engineering First Reinspection $65.00 $0.00 $65.00 Not Paid Reinspection Fee for Building $45.00 $0.00 $45.00 Not Paid Engineering Second Reinspection $65.00 $0.00 $65.00 Not Paid Totals:$841.38 $666.38 $175.00 PLEASE DO NOT SUBMIT ANY PAYMENTS UNTIL A COLLIER COUNTY PAYMENT SLIP IS DISTRIBUTED Total Amount Payable Online: $175.00 Add Fees to My Cart Deposits & Bonds There are no deposits or bonds for this permit application. Inspections Inspection Outcome Requested Scheduled Date Inspected 701 - Pool Final Pending Schedule? Inspector: 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 4/12Page 219 of 303 Corrections: Correction 1:Miscellaneous Corrections Status:Outstanding Date Status Changed:03/29/2024 Comments:Expose four points of connection to shell and equipment bond conductor connection 680.26 /mat Corrections: Correction 1:Inspector Notes Status:Outstanding Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention area etc must be sod only. Just need to see final project done 2. Missing certified engineering letter on file for type 2 storm water condition Correction 2:Inspector Notes Status:Outstanding Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention areas, etc must be sod only. Missing swale/berm on right and left side. Refer to plans. 2. Missing certified engineering letter on file for type 2 storm water condition 708 - Pool Electrical Final Pending Schedule? Inspector: 711 - Pool Footings Pending Schedule? Inspector: 707 - Pool Plumbing Final Pending Schedule? Inspector: 810 - Exotic Vegetation Removal Pending Schedule? Inspector: 714 - Pool Equipotential Bonding Grid Pending Schedule? Inspector: 801 - Site Drainage Pending Schedule? Inspector: 814 - Erosion/Silt Pass 1/22/2024 1/22/2024 01/22/2024 Inspector:Nick Duclos ((239) 789-6198) Send Email 704 - Pool Shell Reinforcement (NOTE:Survey may be required within 10 days) Fail - no fee 1/24/2024 1/24/2024 01/24/2024 Inspector:John Kustra ((239) 877-8117) Send Email 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 5/12Page 220 of 303 Corrections: Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:01/24/2024 Comments:Miscellaneous Corrections Must pass 700, 706 inspections , not scheduled All else ok 1.24.24 Jkustra Corrections: Correction 1:Miscellaneous Corrections Status:Outstanding Date Status Changed:01/24/2024 Comments:Miscellaneous Corrections Must pass 700, 706 inspections , not scheduled All else ok 1.24.24 Jkustra Corrections: Correction 1:Inspector Notes Status:Carried Forward Date Status Changed:03/29/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention area etc must be sod only. Just need to see final project done 2. Missing certified engineering letter on file for type 2 storm water condition 700 - Pool Bonding Pass 1/26/2024 1/26/2024 01/26/2024 Inspector:Joe Justice ((239) 253-3165) Send Email 704 - Pool Shell Reinforcement (NOTE:Survey may be required within 10 days) Pass 1/26/2024 1/26/2024 01/26/2024 Inspector:John Kustra ((239) 877-8117) Send Email 706 - Pool Plumbing Rough Pass 1/26/2024 1/26/2024 01/26/2024 Inspector:Jamel Casado ((239) 631-0161) Send Email 801 - Site Drainage Failed - Building 3/29/2024 3/29/2024 03/29/2024 Inspector:Nick Duclos ((239) 789-6198) Send Email 709 - Pool Pipe Pressure Test Pass 3/29/2024 3/29/2024 03/29/2024 Inspector:Jamel Casado ((239) 631-0161) Send Email 714 - Pool Equipotential Bonding Grid Failed - Building 3/29/2024 3/29/2024 03/29/2024 Inspector:Mark Thomas ((239) 438-5191) Send Email 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 6/12Page 221 of 303 Corrections: Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:03/29/2024 Comments:Expose four points of connection to shell and equipment bond conductor connection 680.26 /mat Corrections: Correction 1:Inspector Notes Status:Carried Forward Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention area etc must be sod only. Just need to see final project done 2. Missing certified engineering letter on file for type 2 storm water condition Correction 2:Inspector Notes Status:Carried Forward Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention areas, etc must be sod only. Missing swale/berm on right and left side. Refer to plans. 2. Missing certified engineering letter on file for type 2 storm water condition 801 - Site Drainage Failed - Building 6/18/2024 6/18/2024 06/18/2024 Inspector:Nick Duclos ((239) 789-6198) Send Email Conditions Condition Status Category Clearing Restrictions Resolved Guidelines For Electronically Submitting Documents: 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 7/12Page 222 of 303 Department:Environmental Services Expiration Date: Due Date: Description:NOTICE OF CLEARING RESTRICTIONS: The issuance of a building permit for a single-family dwelling allows up to one (1) acre of native vegetation to be cleared. Clearing more than one (1) acre may be allowed for accessory structures and requires a separate Vegetation Removal Permit. Properties located in the following zoning district overlays may not be allowed to clear one (1) acre: Rural Fringe Mixed Use District (RFMU), Big Cypress Area of Concern (ACSC), and Special Treatment Overlay (ST). There may be additional restrictions related to clearing native vegetation and impacts to wetlands or protected species found on the property. State and Federal agency permits may be required. Contact the Growth Management Department’s Environmental Services at (239) 252-2400 for additional information. Condition Type:Informational Department:Building Review and Permitting Expiration Date: Due Date: Description:Notice of Commencement: Upload to the condition on the portal. /OR 6233 PG 449 E-Recorded 4/6/2023 Condition Type:Inspection Hold Department:Building Review and Permitting Expiration Date: Due Date: Description:FEMA - All equipment must be above flood plus one foot. Any materials used below flood level must comply with FEMA regulations Condition Type:Informational Department:Building Review and Permitting Expiration Date: Due Date: Description:A Survey is required and must verify that improvement(s) meet setbacks, easements, and elevation requirements per Chapter 62, Collier County Code of Laws and Ordinances. Throughout the duration of the permit, please review the survey conditions for when to upload the survey. Condition Type:Informational Notice of Commencement Resolved FEMA - Equipment and Material Requirements Open Survey will be Required Inactive Elevation Certificate Under Construction Not Required 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 8/12Page 223 of 303 Department:Building Review and Permitting Expiration Date: Due Date: Description:At the time of permit application, the permitted structure is in the special flood hazard area. An Under Construction Elevation Certificate is required within 10 days of passing a 103 or 133 inspection of slab or other foundation system. Prior to obtaining County approval of the Under Construction Elevation Certificate, the permit holder’s construction activities are at his/her own risk. Under Construction Elevation Certificates must verify the slab meets minimum elevations per the Florida Building Code and Chapter 62, Collier County Code of Laws and Ordinances (e.g., BFE +1 or 18” above the crown of the road, whichever is higher, and the elevation established by the SFWMD permit). Condition Type:CO Hold Department:Building Review and Permitting Expiration Date: Due Date: Description:> Elevation Certificate AH 12 NAVD; Pool equipment must be BFE +1 OR Pool exemption letter MartinezMilena 06/02/2023 12:59 PM Condition Type:CO Hold Documents: Department:Building Review and Permitting Expiration Date: Due Date: Description:Sub Contractor (Pool) for Pool Finishing. Upload to the condition on portal. Condition Type:Inspection Hold Department:Engineering Services Expiration Date: Due Date: Description:This building permit has a Type II stormwater management plan, signed and sealed by a registered Florida Professional Engineer as was reviewed by Development Review. Prior to scheduling the 801 inspection, please upload the signed and sealed stormwater certification letter to the condition in the portal. If you have further questions, please contact Engineering Services at 239-252-2417. Condition Type:CO Hold Documents: Department:Building Review and Permitting Expiration Date: Due Date: Description:Sub Contractor (Electrical) Upload to the condition on portal. Elevation Certificate Open Sub Contractor (Pool)Resolved Storm water Type 2 Certification letter Open Sub Contractor (Electrical)Resolved Browse.. Browse.. 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 9/12Page 224 of 303 Condition Type:Inspection Hold Department:Building Review and Permitting Expiration Date: Due Date: Description:Use the form located at https://www.colliercountyfl.gov/home/showdocume nt?id=105797&t=638403984984558370 to request Permit extensions, cancellations, and changes/withdrawals of Contractors, Subcontractors and Qualifiers. Instructions are provided with the form. Change/withdrawal of contractor does not apply to self-issued permits. Contact Building Permit Resolution Services at 239-252-2493 for assistance completing the form. Submit the form by clicking the Browse button below. Condition Type:Informational Documents: Department:Building Review and Permitting Expiration Date: Due Date: Description:Please upload a Spot Survey demonstrating the finished slab or pool shell that meets the required setbacks, easements, and minimum elevation per Chapter 62, Collier County Code of Laws and Ordinances. Prior to obtaining County approval of the Spot Survey, the permit holder’s construction activities are at your own risk. After 10 days an "Inspection HOLD" will be placed on this Permit for survey review. Condition Type:Stipulation Department:Building Review and Permitting Expiration Date: Due Date: Description:Please upload a Spot Survey demonstrating the finished slab or pool shell that meets the required setbacks, easements, and minimum elevation per Chapter 62, Collier County Code of Laws and Ordinances. Prior to obtaining County approval of the Spot Survey, the permit holder’s construction activities are at your own risk. Condition Type:Inspection Hold Department: Expiration Date: Due Date: Description:If a screen enclosure is proposed in the future it will need to meet the 7.5' side setback. Condition Type:Informational Request Changes to Permit Contractors or Status Open Spot Survey Stipulation Inactive Spot Survey Inspection Hold Resolved Miscellaneous Conditions Open Spot Survey CO Hold Resolved Browse.. 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 10/12Page 225 of 303 Department:Building Review and Permitting Expiration Date: Due Date: Description:Please upload a Spot Survey demonstrating that the improvement listed on the permit meets the required setbacks, easements, and minimum elevation per Chapter 62, Collier County Code of Laws and Ordinances as applicable. Condition Type:CO Hold Documents & Images Date Uploaded File Type Name 01/08/2024 Approved Plans (PR)Approved Construction Documents Residential 01/08/2024 Letter Combined Permit and Inspection Job Card 01/08/2024 Response Letter Corrections Response Letter (RESPONSE LETTER - II (Received).pdf ) 01/12/2024 Pedro 209 Permit Collier.pdf 01/16/2024 Subcontractor Affirmation .pdf 03/22/2024 Survey, Certified Site Plans PRSPL20230414398 Approved Final Survey.pdf 04/06/2023 N.O.C.Notice of Commencement (NOC.pdf ) 04/07/2023 Letter Incomplete Application Notice (Generate Incomplete Application Notice) 04/21/2023 Letter Final Incomplete Application Notice (Generate Final Incomplete Notice) 05/23/2023 Letter Payment Slip (PR - App) 05/23/2023 Receipt Receipt for transaction:2023-045474 06/16/2023 Applications Application Form (PRSPL20230414398 - Prepared (Received).pdf) 06/16/2023 Approved Plans (PR)Certifed Site Plan & Construction Plans (011023 209 Mentor Dr (F34_002) SS0 - Prepared (Received).pdf) 06/16/2023 Approved Plans (PR)Construction Plans (011023 209 MENTOR DR (F34_002) HYD SS - Prepared (Received).pdf) 06/16/2023 Approved Plans (PR)Construction Plans (Swimming Pool Safety 209 mentor drive (Received).pdf ) 06/16/2023 Letter Corrections Letter EPR - Outstanding Corrections 07/20/2023 Letter Incomplete Resubmittal Notice (Generate Incomplete Resubmittal Notice) 07/25/2023 Letter Incomplete Resubmittal Notice (Generate Incomplete Resubmittal Notice) 08/14/2023 Letter Corrections Letter EPR - Outstanding Corrections 08/14/2023 Letter Corrections Letter EPR - Outstanding Corrections 08/14/2023 Response Letter Corrections Response Letter (Corrections Response Letter (Received).pdf) 08/14/2023 Approved Plans (PR)Site Planning Document (LOT 220 (Received).pdf ) 08/14/2023 Response Letter Storm Water Plan (Growth Management Department (Received).pdf ) 12/20/2023 Approved Plans (PR)sub3 Storm Water Plan (23-99 209 Mentor Dr Drainage Plan REVISED 12-19-2023.pdf ) 12/21/2023 Letter Payment Slip (RFI-Customer PR) 12/23/2023 Receipt Receipt for transaction:2023-112773 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 11/12Page 226 of 303 5/14/25, 1:37 PM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 12/12Page 227 of 303 Application Number:PRSPL20230414398 Application Type:Pool Application Status:Inspections Commenced Property Owner's Full Name:BOULTER, STUART TINA LOUISE KOBAN Category of Work:New Construction Occupancy Code:Residential, One and Two Family New or Guest House Description of Work:PROPOSED A NEW IN-GROUND CONCRETE POOL 209 Mentor DR, Naples Application Date:04/06/2023 Issued Date:01/08/2024 Expiration Date:08/11/2027 1-2 Family or Comm:1-2 Family Locations:Property 82538000008 Address 209 Mentor DR, Naples Applicant:Rene A. Aviles, Address:2617 Shelby parkway., Phone:(239) 810-4184 Property Owner:BOULTER, STUART TINA LOUISE KOBAN, Address:209 MENTOR DR Qualifier:RENE A. AVILES, Address:2617 SHELBY PARKWAY, Phone:(239) 810- 4184, Licensee # Q29712 License Status SubContractor: Electrical:E & SON ELECTRIC CORP, Address:157 SE 27TH ST, Phone:(239) 541- 2286, State Reg #'s ES12000913, Licensee # LCC20120001340 License Status SubContractor: Pool:FULL CONTRUCTION SERVICES INC, Address:2617 SHELBY PKWY, Phone:(239) 810-4184, State Reg #'s CPC1457891, Licensee # LCC20240000013 License Status Primary Contractor:FULL CONSTRUCTION SERVICES INC, Address:2617 SHELBY PARKWAY, Phone:(239) 810-4184, State Reg #'s CGC1513065, Licensee # C32676 License Status Permit Type:Pool Permit Status:Inspections Commenced Permit Application Status PRSPL20230414398 Summary Locations Contacts Permits (Click to See Reviews) Permit Number: PRSPL2023041439801 1 Initial Submittal Status: Returned for Correction Review Type Outcome Est. Completion Date Completed 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 1/12Page 228 of 303 Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:07/26/2023 Comments:-Per LDC Section 6.05.03, please provide a Type I or Type II stormwater plan that identifies the total lot area, and total impervious (existing plus proposed). If 40% or less of the total lot is impervious area, then a Type I stormwater plan is required and must verify directional flow (flow arrows) of stormwater generated from the proposed improvements will not impact adjacent properties. If more than 40% impervious area, a Type II stormwater plan signed and sealed by a registered professional engineer is required for the excess impervious area. Please note that per LDC Section 6.05.03, pools are considered impervious area. Please see link below for stormwater requirements. http://www.colliercountyfl.gov/home/showdocu ment?id=72831 Final Type Review Complete 07/06/2023 06/16/2023 Reviewer:LEGACY: BerlYves Mercier ((239) 252-2398) Send Email Engineering Review Rejected 06/21/2023 06/15/2023 Reviewer:Didier Diaz ((239) 252-2918) Send Email Corrections: Plumbing and Handicap Review Approved 06/21/2023 06/13/2023 Reviewer:Tobias Hytonen ((239) 252-2659) Send Email Zoning Review Approved 06/21/2023 06/12/2023 Reviewer:LEGACY: Mark Morton ((239) 252-2361) Send Email Floodplain Review Approved 06/21/2023 06/02/2023 Reviewer:Milena Martinez ((239) 252-1448) Send Email 2 Re-Submittal Status: Returned for Correction Review Type Outcome Est. Completion Date Completed Final Type Review Complete 09/07/2023 08/14/2023 Reviewer:Angel Tarpley ((239) 252-5625) Send Email Engineering Review Rejected 08/23/2023 08/14/2023 Reviewer:Didier Diaz ((239) 252-2918) Send Email 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 2/12Page 229 of 303 Correction 1:Miscellaneous Corrections Status:Withdrawn Date Status Changed:08/14/2023 Comments:-Per LDC Section 6.05.03, please provide a Type I or Type II stormwater plan that identifies the total lot area, and total impervious (existing plus proposed). If 40% or less of the total lot is impervious area, then a Type I stormwater plan is required and must verify directional flow (flow arrows) of stormwater generated from the proposed improvements will not impact adjacent properties. If more than 40% impervious area, a Type II stormwater plan signed and sealed by a registered professional engineer is required for the excess impervious area. Please note that per LDC Section 6.05.03, pools are considered impervious area. Please see link below for stormwater requirements. http://www.colliercountyfl.gov/home/showdocu ment?id=72831 Correction 2:Miscellaneous Corrections Status:Carried Forward Date Status Changed:12/20/2023 Comments:-Stormwater Plan Worksheet shows 80 ft as the lot with and 168 ft as the lot depth (Site Plan indicate that the right number would be 136.10 ft) so the total Square footage is 10,888 sf (not 13,120 sf as shown under your calculations), then the total Impervious Area would be 43.46 sf which is over the 40% allowed for an RSF-3 zoning. Per LDC Section 6.05.03 please provide a Type II Stormwater Plan. Corrections: 3 Re-Submittal Status: Complete Review Type Outcome Est. Completion Date Completed Final Type Review Complete 02/06/2024 12/21/2023 Reviewer:Marianella Rothschild ((239) 252-2400) Send Email Engineering Review Approved 01/23/2024 12/21/2023 Reviewer:Didier Diaz ((239) 252-2918) Send Email 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 3/12Page 230 of 303 Correction 1:Miscellaneous Corrections Status:Withdrawn Date Status Changed:12/21/2023 Comments:-Stormwater Plan Worksheet shows 80 ft as the lot with and 168 ft as the lot depth (Site Plan indicate that the right number would be 136.10 ft) so the total Square footage is 10,888 sf (not 13,120 sf as shown under your calculations), then the total Impervious Area would be 43.46 sf which is over the 40% allowed for an RSF-3 zoning. Per LDC Section 6.05.03 please provide a Type II Stormwater Plan. Correction 2:Miscellaneous Corrections Status:Resolved Date Status Changed:12/21/2023 Comments: Corrections: Fees Paid Fees Amount Paid Owing Date Paid Pool or Spa - New Residential - Application $50.00 $50.00 Paid 05/23/2023 Zoning Review - Application $50.00 $50.00 Paid 05/23/2023 Inspection Fee $405.00 $405.00 Paid 12/23/2023 Site Engineering $150.00 $150.00 Paid 12/23/2023 BCAI $6.83 $6.83 Paid 12/23/2023 DBPR Surcharge $4.55 $4.55 Paid 12/23/2023 Engineering First Reinspection $65.00 $65.00 Paid 07/15/2025 Reinspection Fee for Building $45.00 $45.00 Paid 07/15/2025 Engineering Second Reinspection $65.00 $65.00 Paid 07/15/2025 Outstanding Fees Amount Paid Owing Date Paid Reinspection Fee for Building $45.00 $0.00 $45.00 Not Paid Totals:$886.38 $841.38 $45.00 PLEASE DO NOT SUBMIT ANY PAYMENTS UNTIL A COLLIER COUNTY PAYMENT SLIP IS DISTRIBUTED Total Amount Payable Online: $45.00 Add Fees to My Cart Deposits & Bonds There are no deposits or bonds for this permit application. Inspections Inspection Outcome Requested Scheduled Date Inspected 701 - Pool Final Pending Schedule? 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 4/12Page 231 of 303 Corrections: Correction 1:Inspector Notes Status:Outstanding Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention area etc must be sod only. Just need to see final project done 2. Missing certified engineering letter on file for type 2 storm water condition Correction 2:Inspector Notes Status:Outstanding Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention areas, etc must be sod only. Missing swale/berm on right and left side. Refer to plans. 2. Missing certified engineering letter on file for type 2 storm water condition Corrections: Correction 1:Miscellaneous Corrections Status:Outstanding Date Status Changed:09/09/2025 Comments:Expose four points of connection to shell and equipment bond conductor connection 680.26 /mat Inspector: 708 - Pool Electrical Final Pending Schedule? Inspector: 711 - Pool Footings Pending Schedule? Inspector: 707 - Pool Plumbing Final Pending Schedule? Inspector: 810 - Exotic Vegetation Removal Pending Schedule? Inspector: 801 - Site Drainage Pending Schedule? Inspector: 714 - Pool Equipotential Bonding Grid Pending Schedule? Inspector: 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 5/12Page 232 of 303 Correction 2:Miscellaneous Corrections Status:Outstanding Date Status Changed:09/09/2025 Comments:Miscellaneous Corrections: 9/9/25 Several points were exposed of grid only. Please expose four areas where the pool shell is bonded to the equipotential grid around the poo AND the equipment bonding conductor bonding point to the grid and two or more areas where it runs to the equipment pad, No access, unable to inspect bonding points, fbc 110.5 //jt Corrections: Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:01/24/2024 Comments:Miscellaneous Corrections Must pass 700, 706 inspections , not scheduled All else ok 1.24.24 Jkustra Corrections: Correction 1:Miscellaneous Corrections Status:Outstanding Date Status Changed:01/24/2024 Comments:Miscellaneous Corrections Must pass 700, 706 inspections , not scheduled All else ok 1.24.24 Jkustra 814 - Erosion/Silt Pass 1/22/2024 1/22/2024 01/22/2024 Inspector:Nick Duclos ((239) 789-6198) Send Email 704 - Pool Shell Reinforcement (NOTE:Survey may be required within 10 days) Fail - no fee 1/24/2024 1/24/2024 01/24/2024 Inspector:John Kustra ((239) 877-8117) Send Email 700 - Pool Bonding Pass 1/26/2024 1/26/2024 01/26/2024 Inspector:Joe Justice ((239) 253-3165) Send Email 704 - Pool Shell Reinforcement (NOTE:Survey may be required within 10 days) Pass 1/26/2024 1/26/2024 01/26/2024 Inspector:John Kustra ((239) 877-8117) Send Email 706 - Pool Plumbing Rough Pass 1/26/2024 1/26/2024 01/26/2024 Inspector:LEGACY: Jamel Casado ((239) 631-0161) Send Email 801 - Site Drainage Failed - Building 3/29/2024 3/29/2024 03/29/2024 Inspector:Nick Duclos ((239) 789-6198) Send Email 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 6/12Page 233 of 303 Corrections: Correction 1:Inspector Notes Status:Carried Forward Date Status Changed:03/29/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention area etc must be sod only. Just need to see final project done 2. Missing certified engineering letter on file for type 2 storm water condition Corrections: Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:03/29/2024 Comments:Expose four points of connection to shell and equipment bond conductor connection 680.26 /mat Corrections: Correction 1:Inspector Notes Status:Carried Forward Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention area etc must be sod only. Just need to see final project done 2. Missing certified engineering letter on file for type 2 storm water condition Correction 2:Inspector Notes Status:Carried Forward Date Status Changed:06/18/2024 Comments:Inspector Notes: 1. Stabilize all bare dirt adhering to approved type 2 storm water plan. All swales, berms and retention areas, etc must be sod only. Missing swale/berm on right and left side. Refer to plans. 2. Missing certified engineering letter on file for type 2 storm water condition 709 - Pool Pipe Pressure Test Pass 3/29/2024 3/29/2024 03/29/2024 Inspector:LEGACY: Jamel Casado ((239) 631-0161) Send Email 714 - Pool Equipotential Bonding Grid Failed - Building 3/29/2024 3/29/2024 03/29/2024 Inspector:Mark Thomas ((239) 438-5191) Send Email 801 - Site Drainage Failed - Building 6/18/2024 6/18/2024 06/18/2024 Inspector:Nick Duclos ((239) 789-6198) Send Email 714 - Pool Equipotential Bonding Grid Failed - Building 9/9/2025 9/9/2025 09/09/2025 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 7/12Page 234 of 303 Corrections: Correction 1:Miscellaneous Corrections Status:Carried Forward Date Status Changed:09/09/2025 Comments:Expose four points of connection to shell and equipment bond conductor connection 680.26 /mat Correction 2:Miscellaneous Corrections Status:Carried Forward Date Status Changed:09/09/2025 Comments:Miscellaneous Corrections: 9/9/25 Several points were exposed of grid only. Please expose four areas where the pool shell is bonded to the equipotential grid around the poo AND the equipment bonding conductor bonding point to the grid and two or more areas where it runs to the equipment pad, No access, unable to inspect bonding points, fbc 110.5 //jt Department:Environmental Services Expiration Date: Due Date: Description:NOTICE OF CLEARING RESTRICTIONS: The issuance of a building permit for a single-family dwelling allows up to one (1) acre of native vegetation to be cleared. Clearing more than one (1) acre may be allowed for accessory structures and requires a separate Vegetation Removal Permit. Properties located in the following zoning district overlays may not be allowed to clear one (1) acre: Rural Fringe Mixed Use District (RFMU), Big Cypress Area of Concern (ACSC), and Special Treatment Overlay (ST). There may be additional restrictions related to clearing native vegetation and impacts to wetlands or protected species found on the property. State and Federal agency permits may be required. Contact the Growth Management Department’s Environmental Services at (239) 252-2400 for additional information. Condition Type:Informational Department:Building Review and Permitting Expiration Date: Due Date: Description:Notice of Commencement: Upload to the condition on the portal. /OR 6233 PG 449 E-Recorded 4/6/2023 Condition Type:Inspection Hold Inspector:Jeffrey Teston ((239) 877-3168) Send Email Conditions Condition Status Category Clearing Restrictions Resolved Notice of Commencement Resolved FEMA - Equipment and Material Requirements Open Guidelines For Electronically Submitting Documents: 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 8/12Page 235 of 303 Department:Building Review and Permitting Expiration Date: Due Date: Description:FEMA - All equipment must be above flood plus one foot. Any materials used below flood level must comply with FEMA regulations Condition Type:Informational Department:Building Review and Permitting Expiration Date: Due Date: Description:A Survey is required and must verify that improvement(s) meet setbacks, easements, and elevation requirements per Chapter 62, Collier County Code of Laws and Ordinances. Throughout the duration of the permit, please review the survey conditions for when to upload the survey. Condition Type:Informational Department:Building Review and Permitting Expiration Date: Due Date: Description:At the time of permit application, the permitted structure is in the special flood hazard area. An Under Construction Elevation Certificate is required within 10 days of passing a 103 or 133 inspection of slab or other foundation system. Prior to obtaining County approval of the Under Construction Elevation Certificate, the permit holder’s construction activities are at his/her own risk. Under Construction Elevation Certificates must verify the slab meets minimum elevations per the Florida Building Code and Chapter 62, Collier County Code of Laws and Ordinances (e.g., BFE +1 or 18” above the crown of the road, whichever is higher, and the elevation established by the SFWMD permit). Condition Type:CO Hold Department:Building Review and Permitting Expiration Date: Due Date: Description:> Elevation Certificate AH 12 NAVD; Pool equipment must be BFE +1 OR Pool exemption letter MartinezMilena 06/02/2023 12:59 PM Condition Type:CO Hold Documents: Department:Building Review and Permitting Expiration Date: Due Date: Description:Sub Contractor (Pool) for Pool Finishing. Upload to the condition on portal. Condition Type:Inspection Hold Survey will be Required Inactive Elevation Certificate Under Construction Not Required Elevation Certificate Open Sub Contractor (Pool)Resolved Storm water Type 2 Certification letter Open Browse.. 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 9/12Page 236 of 303 Department:Engineering Services Expiration Date: Due Date: Description:This building permit has a Type II stormwater management plan, signed and sealed by a registered Florida Professional Engineer as was reviewed by Development Review. Prior to scheduling the 801 inspection, please upload the signed and sealed stormwater certification letter to the condition in the portal. If you have further questions, please contact Engineering Services at 239-252-2417. Condition Type:CO Hold Documents: Department:Building Review and Permitting Expiration Date: Due Date: Description:Sub Contractor (Electrical) Upload to the condition on portal. Condition Type:Inspection Hold Department:Building Review and Permitting Expiration Date: Due Date: Description:Use the form located at https://www.colliercountyfl.gov/home/showdocume nt?id=105797&t=638403984984558370 to request Permit extensions, cancellations, and changes/withdrawals of Contractors, Subcontractors and Qualifiers. Instructions are provided with the form. Change/withdrawal of contractor does not apply to self-issued permits. Contact Building Permit Resolution Services at 239-252-2493 for assistance completing the form. Submit the form by clicking the Browse button below. Condition Type:Informational Documents: Request Permit Extension.pdf Department:Building Review and Permitting Expiration Date: Due Date: Description:Please upload a Spot Survey demonstrating the finished slab or pool shell that meets the required setbacks, easements, and minimum elevation per Chapter 62, Collier County Code of Laws and Ordinances. Prior to obtaining County approval of the Spot Survey, the permit holder’s construction activities are at your own risk. After 10 days an "Inspection HOLD" will be placed on this Permit for survey review. Condition Type:Stipulation Sub Contractor (Electrical)Resolved Request Changes to Permit Contractors or Status Open Spot Survey Stipulation Inactive Spot Survey Inspection Hold Resolved Browse.. Browse.. 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 10/12Page 237 of 303 Department:Building Review and Permitting Expiration Date: Due Date: Description:Please upload a Spot Survey demonstrating the finished slab or pool shell that meets the required setbacks, easements, and minimum elevation per Chapter 62, Collier County Code of Laws and Ordinances. Prior to obtaining County approval of the Spot Survey, the permit holder’s construction activities are at your own risk. Condition Type:Inspection Hold Department: Expiration Date: Due Date: Description:If a screen enclosure is proposed in the future it will need to meet the 7.5' side setback. Condition Type:Informational Department:Building Review and Permitting Expiration Date: Due Date: Description:Please upload a Spot Survey demonstrating that the improvement listed on the permit meets the required setbacks, easements, and minimum elevation per Chapter 62, Collier County Code of Laws and Ordinances as applicable. Condition Type:CO Hold Miscellaneous Conditions Open Spot Survey CO Hold Resolved Documents & Images Date Uploaded File Type Name 01/08/2024 Approved Plans (PR)Approved Construction Documents Residential 01/08/2024 Letter Combined Permit and Inspection Job Card 01/08/2024 Response Letter Corrections Response Letter (RESPONSE LETTER - II (Received).pdf ) 01/12/2024 Pedro 209 Permit Collier.pdf 01/16/2024 Subcontractor Affirmation .pdf 03/22/2024 Survey, Certified Site Plans PRSPL20230414398 Approved Final Survey.pdf 04/06/2023 N.O.C.Notice of Commencement (NOC.pdf ) 04/07/2023 Letter Incomplete Application Notice (Generate Incomplete Application Notice) 04/21/2023 Letter Final Incomplete Application Notice (Generate Final Incomplete Notice) 05/23/2023 Letter Payment Slip (PR - App) 05/23/2023 Receipt Receipt for transaction:2023-045474 06/16/2023 Applications Application Form (PRSPL20230414398 - Prepared (Received).pdf) 06/16/2023 Approved Plans (PR)Certifed Site Plan & Construction Plans (011023 209 Mentor Dr (F34_002) SS0 - Prepared (Received).pdf) 06/16/2023 Approved Plans (PR)Construction Plans (011023 209 MENTOR DR (F34_002) HYD SS - Prepared (Received).pdf) 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 11/12Page 238 of 303 Date Uploaded File Type Name 06/16/2023 Approved Plans (PR)Construction Plans (Swimming Pool Safety 209 mentor drive (Received).pdf ) 06/16/2023 Letter Corrections Letter EPR - Outstanding Corrections 07/15/2025 Receipt Receipt for transaction:2025-063100 07/20/2023 Letter Incomplete Resubmittal Notice (Generate Incomplete Resubmittal Notice) 07/25/2023 Letter Incomplete Resubmittal Notice (Generate Incomplete Resubmittal Notice) 08/14/2023 Letter Corrections Letter EPR - Outstanding Corrections 08/14/2023 Letter Corrections Letter EPR - Outstanding Corrections 08/14/2023 Response Letter Corrections Response Letter (Corrections Response Letter (Received).pdf) 08/14/2023 Approved Plans (PR)Site Planning Document (LOT 220 (Received).pdf ) 08/14/2023 Response Letter Storm Water Plan (Growth Management Department (Received).pdf ) 08/16/2025 Request Permit Extension.pdf 08/22/2025 Letter Extension Executive Order (Generate Letter Extension Executive Order) 12/20/2023 Approved Plans (PR)sub3 Storm Water Plan (23-99 209 Mentor Dr Drainage Plan REVISED 12-19-2023.pdf ) 12/21/2023 Letter Payment Slip (RFI-Customer PR) 12/23/2023 Receipt Receipt for transaction:2023-112773 9/10/25, 8:20 AM Permit Application Status - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Permit/StatusReference?referenceNumber=PRSPL20230414398 12/12Page 239 of 303 Page 240 of 303 Sec. 22-201.1 - Misconduct—State certified contractors. The following actions by state certified contractors shall constitute misconduct and grounds for discipline pursuant to section 22-202 of this article. (1) Failing or refusing to provide proof of public liability and property damage insurance coverage and workers compensation insurance coverage as required by Florida Statutes. (2) Willfully violating the applicable building codes or laws of the state, city or Collier County. (3) If the CLB finds through its public hearing process that the contractor was found by another county or municipality within the past 12 months, to have committed fraud or a willful building code violation and the CLB finds that such fraud or other willful violation would have been fraud or a willful violation if committed in Collier County or within the respective city. (4) Fraud. Page 241 of 303 Page 242 of 303 1 Larry Zydek From:Larry Zydek Sent:Wednesday, May 14, 2025 2:13 PM To:'fullconstructionservices@yahoo.com' Subject:Expired Permit / Failed Inspections *** PLEASE READ and RESPOND *** Attachments:Permit Application Status - Collier County - CityView Portal.pdf Good afternoon Rene A. Aviles (Qualifier), FULL CONSTRUCTION SERVICES INC License# CGC1513065 Issuance# 32676 Code Violation case: CECV20250005737 Location of Violation: 209 Mentor DR Our office has received a complaint regarding Expired Permit and Failed Inspections at the referenced location. Please note that Permit #PRSPL20230414398 was submitted on January 24, 2024, and is currently in "Expired" status. See attached document for details. This notice serves as a 30-day warning to bring the project into compliance. Please ensure that a permit extension is requested and inspections commenced no later than June 16, 2025. We kindly ask that you keep us informed of any updates regarding the status of the permit. Should you have any questions or need further assistance, please do not hesitate to contact me directly. Please respond to this email to confirm receipt and to acknowledge that you are actively addressing necessary permit requirements. Thank you for your prompt attention to this matter. Best regards, Larry Zydek Page 243 of 303 1 Larry Zydek From:Larry Zydek Sent:Monday, June 16, 2025 8:50 AM To:'fullconstructionservices@yahoo.com' Subject:Code Violation - Permit Requirement ***PLEASE READ and RESPOND*** Hello Rene A. Aviles (Qualifier), FULL CONSTRUCTION SERVICES INC License# CGC1513065 Issuance# 32676 Code Violation case: CECV20250005737 Location of Violation: 209 Mentor DR Our office has received a complaint regarding Expired Permit and Failed Inspections at the referenced location. Please note that Permit #PRSPL20230414398 was submitted on January 24, 2024, and is currently in "EXPIRED" status. The permit remains in “EXPIRED” status as of this date. This notice serves as a second 30-day warning to bring the project into compliance. Please ensure that a permit extension is requested and inspections commenced no later than July 16, 2025. If the permit is not issued by the end of business on July 16, 2025, we will be reviewing this case with the Collier County Building Department for a possible WILLFUL CODE VIOLATION. Your appearance may be required at a future Contractor Licensing Board hearing. We kindly ask that you keep us informed of any updates regarding the status of the permit. Should you have any questions or need further assistance, please do not hesitate to contact me directly. Please respond to this email to confirm receipt and to acknowledge that you are actively addressing necessary permit requirements. Thank you for your prompt attention to this matter. Best regards, Page 244 of 303 1 Larry Zydek From:Larry Zydek Sent:Tuesday, July 15, 2025 10:38 AM To:Fullconstructionservices@yahoo.com Cc:Larry Zydek Subject:Code Violation - Permit Requirement ***PLEASE READ and RESPOND*** Importance:High Hello Rene A. Aviles (Qualifier), FULL CONSTRUCTION SERVICES INC License# CGC1513065 Issuance# 32676 Code Violation case: CECV20250005737 Location of Violation: 209 Mentor DR Our office has received a complaint regarding Expired Permit and Failed Inspections at the referenced location. Please note that Permit #PRSPL20230414398 was submitted on January 08, 2024, and is currently in "EXPIRED" status (expired 09-25-2024). The permit remains in “EXPIRED” status as of 07-15-2025. This notice serves as a third and FINAL 30-day warning to bring the project into compliance. Please ensure that a permit extension is requested and inspections commenced no later than August 15, 2025. If the permit is not issued by the end of business on August 15, 2025, we will be reviewing this case with the Collier County Building Department for a possible WILLFUL CODE VIOLATION. Your appearance may be required at a future Contractor Licensing Board hearing. We kindly ask that you keep us informed of any updates regarding the status of the permit. Should you have any questions or need further assistance, please do not hesitate to contact me directly. Please respond to this email to confirm receipt and to acknowledge that you are actively addressing necessary permit requirements. Thank you for your prompt attention to this matter. Respectfully, Page 245 of 303 2 Larry Zydek Code Enforcement Officer I Code Enforcement Mobile:239-821-7553 CONTRACTOR LICENSING - 2800 N Horseshoe City of Naples, FLORIDA 34104 Larry.Zydek@colliercountyfl.gov Under Florida Law, e-mail addresses are public records. If you do not want your e-mail address released in response to a public records request, do not send electronic mail to this entity. Instead, contact this office by telephone or in writing. Page 246 of 303 BEFORE THE COLLIER COUNTY CONTRACTORS' LICENSING BOARD BOARD OF COUNTY COMMISSIONERS, COLLIER COUNTY, FLORIDA, Petitioner, V. Benjamin A Lopez (OBA) Top Quality Contractors LLC Respondent. --------------------·' ADMINISTRATIVE COMPLAINT Case No: 2025-14 LCC20220000701 CEMIS20250004648 Collier County (County) files the Administrative Complaint against BENJAMIN A LOPEZ (Respondent), a State Certified Residential Contractor (Collier County Issuance No. 202200000908), and states the following facts and allegations in support of the cited violations below: 1. The Respondent is currently the Certificate Holder by the State of Florida as a CERTIFIED RESIDENTIAL CONTRACTOR (License No. CRC1333212) 2. The Respondent, BENJAMIN A LOPEZ, is the qualifier of record for TOP QUALITY CONTRACTORS LLC listed under Collier County qualifier record 20140000414. 3. Under the provisions of Chapter 489 Florida Statutes §489.105(12) F.S. and the Collier County Code of Laws and Ordinances Sec. 22-202, the Collier County Contractors' Licensing Board (Board), is authorized to impose penalties against State of Florida Certificate of Competency holders who violate the Collier County Code of Laws and Ordinances. 4. Under the provisions of the Collier County Code of Laws and Ordinances Sec 22- 202 the actions of the respondent constitute misconduct and grounds for discipline, 5. On April 18th, 2025, the Collier County Licensing Department received a public portal complaint from Princess Morrison, property owner, for an expired permit and failed inspection at 5254 31st PL SW, Naples. FL. A Contractor Licensing case # CEMIS20250004648 was opened to investigate the complaint. 6. Upon investigation, it was discovered on September 16th, 2023, TOP QUALITY CONTRACTORS LLC entered into a contract with property owner John A Morrison, for a new block paver driveway, to install new 4x4 Culvert to the main property entrance. The contracted amount was for $17,375.00. An initial deposit of Page 247 of 303 $7,000.00 was made in September 2023. A second payment of $7,000.00 was made in December 2023. A third payment of $3,375.00 would be paid on completion of this job and permit(s) finaled. 7. On November 8, 2023, permit # PRROW20230938970 was issued to remove an asphalt driveway and install new pavers 21' wide. 8. On September 18, 2024, the 800 -Right of Way Final Inspection failed for (1) missing footers, (2) swales not being graded and sodded, and (3) wooden form boards on mitered ends not removed. 9. On November 2, 2024, permit# PRROW20230938970 expired. 10.On March 10, 2025, permit application #PRROW20250310030 was submitted and subsequently denied on March 14, 2025. The denial was based on the use of an outdated Authorization Form from the original permit application and the need to revise the ROW plans to: (1) reflect a maximum driveway width of 24 feet, (2) maintain a minimum distance of 7.5 feet from the side property line, and (3) clarify and correct inconsistencies in side measurements across all plan pages. 11. On April 22, 2025, Investigator Simmonds verified the right of way work had been completed. 12. On April 22, 2025, Investigator Simmonds spoke to the Respondent about the complaint, expired permit, failed 800 final inspections, and issued a formal 30-day notice to the Respondent advising of the deficiencies and directing correction of the failed inspection. 13. On May 28, 2025, a review of County records revealed that no corrective action had been taken on permit # PRROW20250310030 and the BOO-inspection remained failed. 14. On May 28, 2025, Investigator Simmonds issued a second 30-day notice to the Respondent directing correction of the failed inspection. 15. On July 19, 2025, a review of County records revealed that no corrective action had been taken on permit # PRROW20250310030 and the 800-inspection remained failed. 16. On July 22nd, 2025, a review of the County records revealed that no permit has been reactivated/issued, with no attempts to correct the building code violation. Attempts to remedy the issue via telephone and email to the Respondent, most recently on 19th July, were unsuccessful. 17. On July 23, 2025, Collier County Chief Building Official formally determined that the matter constituted a willful code violation for being non-responsive and inaction. 18. Based on the investigation, and pursuant to Collier County Code of Law and Ordinances Section 22-202(a)(2) and (b), the Contractors' Licensing Supervisor determined sufficient cause exists to warrant the filing of formal charges. Page 248 of 303 19. On Ju ly 24th, 2025, a Notice of Hearing to appear before the Collier County Contractors' Licensing Board on September 17, 2025, at 9:00 am, was sent to the Respondent's address at 11314 Sunray DR, Bonita Springs, by USPS Certified Ma il. Tracking Number showed unsuccessful delivery. 20.On August 12th, 2025, a Notice of Hearing for September 17, 2025, at 9:00am, was served in person to Isabel Lopez, a fam i ly member over 15 years of age, at the registered address listed on sunbiz.org, Division of Corporations for the State of Florida 21.The County now brings the following count(s) in this Administrative Complaint against the Respondent: COUNT I A.Upon review of County permitting records, the Respondent has failed their obligations as a contractor to renew permit# PRROW20250310030 or apply for a new permit, and resolve the failed 800 - Right of Way Final Inspection. B.Chief Building Official Fred Clum reviewed the ongoing case and determined that the Respondent willfully failed to obtain the required permit renewal and address the failed inspection, which constitutes a willful code violation C.BENJAMIN A LOPEZ is in violation of Collier County Code of Laws and Ordinances Section 22-201.1 (2), which states, in pertinent part, that it is misconduct by a holder of a State of Florida license to willfully violate the applicable building codes or laws of the state, city, or Collier County. WHEREFORE, the Petitioner asserts the above facts and charges are grounds for disciplinary action under Collier County Code of Laws and Ordinances Sec. 22-201 and, WHEREFORE, in consideration of the foregoing, the Petitioner respectfully requests the Collier County Contracto rs' Licensing Board to find the Respondent guilty of the violation(s) charged. Dated: ___.rt�---/0_.,,, Z-_S' __ Signed: �-��:""":-----:-=--�>'-t,C.----- C on tractors' Licen Page 249 of 303 Contractors' Licensing Board 2800 orth Horseshoe Dr. Naples, FL 34104 Complaint Case Number: 2025-14 Complainant: Any person who believes that a Contractor holding a State Certification or Certificate of competency has violated Collier County Ordinance 90-105, as amended, may submit a sworn complaint to the Contractor Licensing supervisor, or his/her designee. The complaint shall be in substantially the form prescribed by the Contractor Licensing Supervisor. The complaining party shall state with particularity which section(s) of this Ordinance he or she believes has been violated by the contractor and the essential facts in support thereof. Complaint: Please print or type and return signed copies of the complaint. Date: September 1 51, 2025 Against: Contractor's Name: Benjamin A LOPEZ Phone: (239) 287-3170 Business Name: Top Quality Contractors LLC License(s) Held: Certified Residential Contractor Collier County Issuance #(s): 202200000908 Contractor's Business Address: 11314 SUNRAY DR, BO ITA SPRINGS. FL, 34145 Filed By: Name: Collier County Contractor Licensing Officer/ Anthony D Simmonds Address: 2800 . Horseshoe Dr., Naples, FL 34104 Business Phone: 239-631-9615 Address where work is done: 5254 31 ST PL SW. City: Naples County: Collier Page 250 of 303 Date of contract: December 23 rd 2023 Date job started: November 14th 2023 Date job completed or new home occupied: N/A Were there plans and pecifications? Yes Is there a written contract? Yes If ye , amount of Contract: $17.375.00 Has the Contractor been paid in full'! No If not, what amount? N/A Was a Building Permit obtained? No Was a Building Permit required? Yes Building Permit number if known: PRROW20230938970 Have you communicated by letter with the licensee? Yes Date: April 22nd 2025 Do you have a reply? Yes Please attach to this form all copies of the purchase agreement, building contract, home improvement contract, copies of receipts and/or cancelled checks available and any additional evidence to substantiate your allegations. List any subsections of Collier County Ordinance number 22-201, which, in your opinion, have been violated by the contractor, which is tbe subject of this complaint, (list subsection number): a.Collier County Ordinance 22-201.1 (2) Willfully violating the applicable building codes or laws of the tate, city or Collier County. Please state the facts which you believe substantiate your charge of misconduct against the sub_jcct contractor. List facts separately for each subsection number above: a.Collier County Ordinance 22-201.J (2) Willfully violaling lhe applicable building codes or laws of the state. city or Collier County. l. The Respondent, Benjamin LOPE.Z failed his obligation as a contractor, to renew permit # PRROW20250310030 or apply for a new permit, and resolve the failed 800 - Right of Way Final Inspection. Page 251 of 303 Anthony D Simmonds Code Enforcement Investigator-Licensing State of _FLORIDA ______ County of_COLLIER._-,--___ _ The foregoing instrument was acknowledged before me by means of .0\physical presence or D onJine notarization on this _3_ day of~ kflC-. , 20 ~S-= by Such person(s) Notary Public must check applicable box: ~ are personally know11 to me 0 has produced a current driver license □ has produced ____________ as identification. (Notary Seal) Notary Signature: _ifl---1..--~--~d/~'~------ ,,-vr1,# ~ ,, •••.. ~ HE1.EN BUCHILLON • ... luJJ! • Commission fHH6518t9 ~~~ ExPifes May 15. 2029 on~" Page 252 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net Date: July 24th, 2025 Benjamin Lopez Top Quality Contractors LLC 11314 Sunray DR, Bonita Springs. Florida 34135 RE: Case # CEMIS20250004648 – 5254 31ST PL SW. Naples, Florida Date of Violation: November 2nd, 2024 Violation: Failure to act following County staff's directive to reactivate expired permit #PRROW20230938970 and address the Corrections for – Final inspection. Dear Sir/Madam, A complaint has been filed against you by the above referenced entity. A hearing of this complaint will be held by the Contractors’ Licensing Board on Wednesday September 17th, 2025, at 9:00 AM in the Board of County Commissioner’s Room, Third Floor, Administration Building (W. Harmon Turner Bldg.), at 3301 East Tamiami Trail, Naples, Florida 34112. Your presence before the Collier County Contractors’ Licensing Board is required at this time. The packet concerning your case marked composite exhibit “A” will be delivered to the members of the Contractors’ Licensing Board one week prior to the hearing. If you wish to receive a copy of this packet, please notify the Contractor Licensing Customer Service Office. If you wish to prepare a defense packet and have it delivered in conjunction with composite exhibit “A”, you must make fifteen copies and have them in our office by 8:00 AM on Wednesday, one week prior to the hearing. In your packet, you may give a summary of events. At this meeting, you may present evidence and be represented by an attorney of your choice. In the event the Contractors’ Licensing Board finds you in violation of Sec. 22-201.1 of the Collier County, FL Code of Ordinances: Sec. 22-201.1 – MISCONDUCT – State Certified Contractors The following actions by state certified contractors shall constitute misconduct and grounds for discipline pursuant to section 22-202 of this article. Page 253 of 303 Growth Management Division Planning & Regulation Operations Department Licensing Section Growth Management Division*Planning & Regulation*2800 North Horseshoe Drive*Naples, Florida 34104*239-252-2400*www.colliergov.net (2) Willfully violating the applicable building codes or laws of the state, city, or Collier County. The range of disciplinary sanctions which may be imposed are (1) denial of Collier County/City building permits or require the issuance of permits with specific conditions; (2) recommendation for suspension, revocation, or restriction of your certificate of competency, or a fine to be levied by the Construction Industry Licensing Board. Sincerely, Anthony D Simmonds Code Enforcement Collier County Contractors’ Licensing Code Enforcement Division 2800 N. Horseshoe Dr., Naples, FL. 34104 239-252-2450 Anthony.simmonds@colliercountyfl.gov Page 254 of 303 Page 255 of 303 Page 256 of 303 Page 257 of 303 Page 258 of 303 Page 259 of 303 Parcel Number:36435280003 Status:Active Legal Description:GOLDEN GATE UNUT 7 BLK 237 LOT 2 Acres:0.23 Bald Eagle Nest Buffer?:No Block:237 CCSL?:No FLN:36435280003 Improvement Value:$191,881.00 Land Value:$202,500.00 Map Number:4B28 Range:26 Section:28 SQ Last Updated:07/30/2025 Taxes:$892.96 Township:49 Use Code:1 Property Review Parcel Number: 36435280003 Property Details Addresses Street #Pre-Direction Street Name Direction Unit #Status 5254 31st PL SW Active 5254 31st PL SW Inactive Contacts Type Description Property Owner MORRISON, JOHN A & PRINCESS R, Address:5254 31ST PL SW Historic Owner MORRISON, JOHN A & PRINCESS R, Address:5254 31ST PL SW Historic Owner MORRISON, JOHN A & PRINCESS R, Address:5254 31ST PL SW Code Enforcement Complaints Case Number Type Status Date Entered CEMIS20250004648 Misconduct Refer to CLB 04/18/2025 Description: I am told that a Permit was issued for the driveway but the contractor agreed works outside of this permit scope to include repair to a congrete Culvert, this work was rejected. Unpermitted relacement of Culvert UNPERMITTED CULVERT INSTALLED BEFORE PERMT ISSUED CEA20190010344 Animals Closed 08/22/2019 8/27/25, 9:18 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO36435280003 1/3Page 260 of 303 Case Number Type Status Date Entered Description: There have been several rats in the yard at 3190 52nd Ln SW, and the owner is concerned. She thinks there migh be a neighbor raising & slaughtering rabbits, causing rats to come onto her property. 2006060187 Vehicles Closed 06/07/2006 Description: [CC_DESC:][CC_DISP:] 2006060064 Legacy - Zoning Closed 06/06/2006 Description: [CC_DESC:][CC_DISP:] 2006060097 Legacy - Zoning Closed 06/06/2006 Description: [CC_DESC:][CC_DISP:] 90223108 Legacy - Zoning Closed 02/23/1999 Description: [CC_DESC:BOAT IN FRT YARD][CC_DISP:CASE CLOSED] 50905081 Legacy - Environmental Closed 09/05/1995 Description: [CC_DESC:WEEDS OVER 18"][CC_DISP:NO VIOLATION] License Applications No records were found. Permit Applications Application Number Type Work Class Status Date Issued PRBD20201149068 Building Alteration/Remodel Finaled 12/07/2020 Permits: Description: Install garage door size for size 16 x 7 Haas 2500 5254 31st PL SW PRBD20200939531 Building Alteration/Remodel Finaled 10/08/2020 Permits: Description: CABINETS & COUNTERTOPS REMODEL IN KITCHEN 5254 31st PL SW, Naples PRBD20170204201 Building Alteration/Remodel Finaled 02/07/2017 Permits: Description: SHINGLE RE-ROOF 5254 31ST PL SW LOT #2 Mechanical, Electrical, Plumbing, Gas & Fire Permit Applications No records were found. 8/27/25, 9:18 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO36435280003 2/3Page 261 of 303 Right of Way, Sign & Well Permit Applications Application Number Type Work Class Status Date Issued PRROW20250310030 Right Of Way Alteration/Remodel Denied Permits: Description: Removing asphalt and installing pavers PRROW20230938970 Right Of Way Alteration/Remodel Inspections Commenced 11/08/2023 Permits: Description: Remove existing asphalt and install new pavers 21' wide. 5254 31st PL SW, Naples Planning Applications No records were found. Special Events, Zoning Certificates, Temporary Use, Short-Term Vacation Rental Registration, RV & Garage Sale Permit Applications No records were found. Environmental Permit Applications No records were found. 8/27/25, 9:18 AM Property Review - Collier County - CityView Portal https://cvportal.colliercountyfl.gov/CityViewWeb/Property/PropertyReview?searchKey=code&searchValue=PRO36435280003 3/3Page 262 of 303 Report Title: Date: Code Case Details 8/26/2025 8:22:40 AM Case Number:CEMIS20250004648 Case Information CEMIS20250004648Case Number: Case Type: Priority: Misconduct Normal Inspector: Jurisdiction: Origin: Anthony.Simmonds Collier County Complaint Detail Description:I am told that a Permit was issued for the driveway but the contractor agreed works outside of this permit scope to include repair to a congrete Culvert, this work was rejected. Unpermitted relacement of Culvert UNPERMITTED CULVERT INSTALLED BEFORE PERMT ISSUED Location Comments:5254 31st PL SW, Naples P# 35435280003 Refer to CLBStatus: Date & Time Entered: Entered By: 4/18/2025 10:15:31 AM JosephMarino Case Disposition:Case Pending Address 5254 31st PL SW, Naples Property 36435280003 Address Location Primary Contractor Top Quality Contractors LLC Complainant MORRISON, JOHN A & PRINCESS R Property Owner MORRISON, JOHN A & PRINCESS R Contacts 1Business Management & Budget Office Page 263 of 303 Execution Date 8/26/2025 8:22:40 AMCode Case Details Investigations Desc Assigned Required Completed Outcome Comments Preliminary Investigation Anthony.Simm onds 4/18/2025 4/22/2025 Needs Investigatio n Recieved a complaint from Upervisor Bogart of a possible Un-permitted re-block to drive way and alteration/repair to a Culvert. GMD Portal showing no permit application for both parts of this job. ADDRESS: 5254 31st Ave SW. PROPERTY OWNER: MORRISON, Princess COMPLAINANT: MORRISON, Princess COMPLAINT: Unable to get Contractor to Final the Permit CONTRACTOR: Top Quality Contractors LLC LICENSE#: CRC1333213 PERMIT#: STATUS: AS OF: CE Staff Review JosephMarino 4/18/2025 4/18/2025 Complete COMPLAINANT - PRINCESS MORRISON, 239-821-4423, 5254 31st PL SW, Naples CONTRACTOR - TOP QUALITY CONTRACTORS LLC, LCC20220000701 - 11314 SUNRAY DR, BONITA SPRINGS FL 34135 B.ANDRES1120@GMAIL.COM - (239) 405- 0500 DOCUMENTS UPLOAD TO CASE, DRIVEWAY HAS BEEN COMPLETED PAVER TO STONE BLOCK, PERMIT APPLICATION FILED AND DENIED. CONTRACTOR STOPPED ALL CONTACT WITH COMPLAINANT. MarinoJoseph 04/18/2025 10:20 AM CE Staff Review MichaelBogert 4/18/2025 4/18/2025 Complete BogertMichael 04/18/2025 4:22 PM See staff comments. Verify Complainant Anthony.Simm onds 4/21/2025 4/21/2025 Verified Called the Complainant and verified the complaints and arranged a site visit Attach Picture(s)Anthony.Simm onds 4/21/2025 4/22/2025 Complete PIctures of the work to drive way and Culvert repair. Cont. Investigation Anthony.Simm onds 4/22/2025 4/22/2025 Complete Pictures provided by the homeowners have been forwarded to Roger moore for Permit Determination. I called the Contractors 239-405-0500 and asked for the Manager or qualifier to return my call to discuss this complaint. Cont. Investigation Anthony.Simm onds 4/22/2025 4/22/2025 Complete I spoke to Mr Benjamin Lopez DBA Top Quality Construction LLC 239-405-0500. I explained the complaint, and adviced him that now the two permits had expired as rejected, he would have to re submit an application for New Permits. i explained that he would receive a email from explaining the status and why the permits had expired along with a 30 Day Permit Notice, and that Collier County would expect some progress on the New Permits within this time line. 2Business Management & Budget Office Page 264 of 303 Execution Date 8/26/2025 8:22:40 AMCode Case Details Desc Assigned Required Completed Outcome Comments Issue Stop Work Order Anthony.Simm onds 4/22/2025 4/22/2025 Complete SWO Posted Cont. Investigation Anthony.Simm onds 5/28/2025 5/28/2025 Complete Email sent to Qualifier on 21st May for an update on the Permit application. I recieved an email reply on 28th May informing me that he was applying for his License renewal so he could satisfy this failed Permit. (emails in Images) CE Phone Call Anthony.Simm onds 7/19/2025 7/19/2025 Complete I attempted to speak to Mr Benjamin Lopez DBA Top Quality Construction LLC 239-405- 0500. The person who answered his phone said he was Carlos and would pass on a message to contact me and confirm his address to send a Notice of Hearing. Cont. Investigation Anthony.Simm onds 7/23/2025 7/23/2025 Complete Recieved no phone call or email reply from Benjamin LOPEZ asking him to confirm his mailing Address as per my previous call. I have sent on 07/23/2025 by USPS CERT MAIL # 9589-0710-5270-2143-6151-48 a Collier County Notice of Hearing before the CLB, to be heard on the 17th September. scanned to images Fred Clum signed the Permit document as a WILFUL Non Responsive. 7/23/2025. scanned to images Cont. Investigation Anthony.Simm onds 7/24/2025 7/24/2025 Complete Ammended Notice of Hearing sent to Qualifier, Correction to Violation from Collier County offence to State Violation. USPS CERT MAIL # 9589-0710-5270-2143- 6151-62 sent 07/24/2025. (scanned to images) Investigation Anthony.Simm onds 7/24/2025 8/4/2025 Refer to CLB ADDRESS: 5254 31st Ave SW. PROPERTY OWNER: MORRISON, Princess COMPLAINANT: MORRISON, Princess COMPLAINT: Unable to get Contractor to Final the expired Permit CONTRACTOR: Top Quality Contractors LLC LICENSE#: CRC1333213 PERMIT#: STATUS: AS OF: Schedule for CLB MichaelBogert 8/4/2025 8/4/2025 Complete BogertMichael 08/04/2025 6:12 PM Scheduled for 9-17-2025 CLB Generate CLB Notice of Hearing MichaelBogert 8/4/2025 8/4/2025 Complete BogertMichael 08/04/2025 6:12 PM Notice of Hearing generated 7-24-2025 by Inv. Simmonds. Enter Hearing Results Anthony.Simm onds 8/5/2025 Pending 9-17-2025 CLB ****f/up notice of hearing service***** 2025-12 22-201(2) ...willfully violating City, County, State, building, zonings laws or ordinances. Contractor - Top Quality Contractors LLC LICENSE#: CRC1333213 3Business Management & Budget Office Page 265 of 303 Execution Date 8/26/2025 8:22:40 AMCode Case Details Desc Assigned Required Completed Outcome Comments Cont. Investigation Anthony.Simm onds 8/12/2025 8/12/2025 Complete Unsuccessful delivery of NOH using USPS Cert Mail. I called at the address on record and handed the Notice of Hearing to a Mrs Isabel LOPEZ who confirmed that Benjamin does live at this address but is at work. Mrs LOPEZ signed for the delivery and told me she would deliver it to Mr Benjamin LOPEZ. (Date/time stamped picture in images) Violations Violation Description Status Entered Corrected Amount Comments Hearings Title Reason Result Compliance Fine/Day Condition 4Business Management & Budget Office Page 266 of 303 Page 267 of 303 Page 268 of 303 Page 269 of 303 Page 270 of 303 Page 271 of 303 Page 272 of 303 Select Year: 2025 v ~ The 2025 Florida Statutes Title XXXII Cha12ter 489 View Entire Cha12ter REGULATION OF PROFESSIONS AND OCCUPATIONS CONTRACTING 489.105 Definitions.-As used in this part: (1) "Board" means the Construction Industry Licensing Board. (2) "Department" means the Department of Business and Professional Regulation . (3) "Contractor" means the person who is qualified for, and is only responsible for, the project contracted for and means, except as exempted in this part, the person who, for compensation, undertakes to, submits a bid to, or does himself or herself or by others construct, repair, alter, remodel, add to, demolish, subtract from, or improve any buildi ng or structure, including related improvements to real estate, for others or for resale to others ; and whose job scope is substantially similar to the job scope described in one of the paragraphs of this subsection. For the purposes of regulation under this part, the term "demolish" applies only to demolition of steel tanks more than 50 feet in height; towers more than 50 feet in height; other structures more than 50 feet in height; and all buildings or residences. Contractors are subdivided into two divisions, Division I, consisting of those contractors defined in paragraphs (a)-(c), and Division II, consisting of those contractors defined in paragraphs (d)-(q): (a) "General contractor" means a contractor whose services are unlimited as to the type of work which he or she may do, who may contract for any activity requiring licensure under this part, and who may perform any work requiring licensure under this part, except as otherwise expressly provided in s. 489.113 . (b) "Building contractor" means a contractor whose services are limited to construction of commercial buildings and single-dwelling or multiple-dwelling residential buildings, which do not exceed three stories in height, and accessory use structures in connection therewith or a contractor whose services are limited to remodeling, repair, or improvement of any size building if the services do not affect the structural members of the building. (c) "Residential contractor" means a contractor whose services are limited to construction, remodeling, repair, or improvement of one -family, two-family, or three-family residences not exceeding two habitable stories above no more than one uninhabitable story and accessory use structures in connection therewith. (d) "Sheet metal contractor" means a contractor whose services are unlimited in the sheet metal trade and who has the experience, knowledge, and skill necessary for the manufacture, fabrication, assembling, handling, erection, installation, dismantling, conditioning, adjustment , insulation, alteration, repair, servicing, or design, if not prohibited by law, of ferrous or nonferrous metal work of U.S. No. 10 gauge or its equivalent or lighter gauge and of other materials, including, but not limited to, fiberglass, used in lieu thereof and of air-handling systems, including the setting of air-handling equipment and reinforcement of same, the balancing of air-handling systems, and any duct cleaning and equipment sanitizing that requires at least a partial disassembling of the system . (e) "Roofing contractor" means a contractor whose services are unlimited in the roofing trade and who has the experience, knowledge, and skill to install, maintain, repair, alter, extend, or design, if not prohibited by law, and use materials and items used in the installation, maintenance, extension, and alteration of all kinds of roofing, waterproofing, and coating , except when coating is not represented to protect, repair, waterproof, stop leaks, or extend the life of the roof. The scope of work of a roofing contractor also includes all of the following and any related work: skylights; required roof-deck attachments; any repair or replacement of wood roof sheathing or fascia as needed during roof repair or replacement; and the evaluation and enhancement of roof-to-wall connections for structures with wood roof decking as described in Section 706 of the Florida Building Code-Existing Building, provided that any enhancement, which was properly installed and inspected in accordance with the Office Page 273 of 303 Page 274 of 303 Page 275 of 303 Page 276 of 303 Page 277 of 303 Page 278 of 303 Page 279 of 303 Page 280 of 303 Page 281 of 303 Page 282 of 303 Page 283 of 303 Right of Way, Sign & Well Permit Application Status Summary Locations Contacts /c Application Number: Application Type: Application Status: Property Owner's Full Name: Category of Work: Occupancy Code: Description of Work: PRROW20230938970 PRROW20230938970 Right Of Way Inspections Commenced MORRISON, ]OHN A & PRINCESS R Alteration/Remodel Residential, One and Two Family New or Guest House Remove existing asphalt and install new pavers 21' wide. 5254 31st PL SW Naples Application Date: 09/15/2023 Issued Date: 17/O8/2O23 Expiration Date: 7l/02/2024 1-2 Family or Comm: 1-2 Family Locations: Propefty 36435280003 trr /v- (lt I tl /t 0l t ,1,(t, Property Owner: Applicant: Qualifier: Address 5254 31st PL SW,Iap_leS 1 MORRISON, JOHN A & PRINCESS R, Address:5254 31ST pL SW Benjamin Lopez, Address:11314 Sunray Dr, phone:(239) 405-0500 LOPEZ, BENJAMIN ANDRES, Address: tt374 SUNRAy DR., phone:(239) 287 -317 O, Licensee # 1CC20140000474 License Status TOP QUALITY CONTRACTORS LLC, Address: tt3t4 SUNRAY DR, phone: (239) 405-0500, State Reg #'s CRC1333212, Licensee # 1CC20220000701 License Status Completed 70/16/2023 Primary Contractor: Permits (Click to See Reviews) Permit Number: PRROW2023093897001 Permit Type: ROW Residential Permit Status: Inspections Commenced 1 Initial Submittal Status: Returned for Correction Rejected Review Type Outcome Est. Completion Date Reviewer: Tami Buchan ((239) 252-6254) Send Email FinalType Review 1.O/02/2023Completet0/1.6/2023 ROW Review Reviewer: Alma Serna Brito ((239) 252-2707) Send Email t0/02/2023 t, Page 284 of 303 Correction 1: Miscellaneous Corrections Status: Carried Forward Date Status Changed: 10/30/2023 Corrections Comments: Correction 2: Status: Date Status Changed: Comments: Correction 3: Status: Date Status Changed: Comments: Correction 4: Status: Date Status Changed: Please be aware since the work has started, it is responsibility of the owner to demolish and re- do any work necessary to meet all of Collier County ROW requirements, and to construct driveway as per Approved Driveway Form that will be provided when permit gets approved, Driveway setback Carried Forward 70l30/2023 Driveway shall be setback a minimum of 7.5 feet from side property line measured at the front property line / right of way line. Please revise Site Plan and resubmit corrected to show meeting this requirement. Driveway culvert Carried Forward L0/30/2023 Please indicate the culvert material. Acceptable culvert (pipe) materials include PVC Class A- 2000 - poly vinyl chloride (double walted), HDpE high density polyethylene (double walled, smooth interior), RCP reinforced concrete, or CMP corrugated metal. The required culvert diameter (Must be 15") (Must be 38' long) and elevations with which to install the culvert will be provided with the approved permit documents. Miscellaneous Corrections Carried Forward 70/30/2023 Comments: Please be aware there must be a foot of cover over the culvert. Correction 5: Miscellaneous Corrections Status: Carried Forward Date Status Changed: 10/30/2023 Comments: Please be aware there must be a minimum of 2' safety zone from end of driveway to start of mitered end. Page 285 of 303 2 Re-Submittal Corrections I Status: Complete ROW Review Approved Reviewer: Alma Serna Brito ((239) 252-2tO7) Send Email Correction 1: Miscellaneous Corrections Status: Resolved Date Status Changed: 17/08/2023 Corrections Correction 6: Response Letter Status: Carried Forward Date Status Changed: |O/3O/2O23 Comments: Correction 2: Status: Date Status Changed: Comments: Correction 3: Status: Date Status Chanoed: Comments: Comments: Please provide a written letter of response summarizing the changes made to address each correction comment, it must be included in your resubmittal. Failure to include a written letter of response could result in a rejection. 17/2t/2023 77/08/2023 Please be aware since the work has started, it is responsibility of the owner to demolish and re- do any work necessary to meet all of Collier County ROW requirements, and to construct driveway as per Approved Driveway Form that will be provided when permit gets approved. Driveway setback Resolved tt/08/2023 Driveway shall be setback a minimum of 7.5 feet from side property line measured at the front property line / right of way line. please revise Site Plan and resubmit corrected to show meeting this requirement. Driveway culvert Resolved tt/08/2023 Please indicate the culvert material. Acceptable culvert (pipe) materials include PVC Class A- 2000 - poly vinyl chloride (double wailed), HDpE high density polyethylene (double walled, smooth interior), RCP reinforced concrete, or CMP corrugated metal, The required culvert diameter (Must be 15") (Must be 38, long) and elevations with which to install the culvert will be provided with the approved permit documents. F,,"*Review Type e Est. Completion Date Completed Reviewer: Tami Buchan ((239) 252-6254) Send Email Final Type Review L7/08/2023Completet7/27/2023 Page 286 of 303 Correction 4: Status: Date Status Chanoed: M iscel la neous Corrections Resolved t7/08/2023 Comments: Please be aware there must be a foot of cover over the culvert. Correction 5: Miscellaneous Corrections Status: Resolved Date Status Changed: 7L/08/2023 Comments: Please be aware there must be a minimum of 2, safety zone from end of driveway to start of mitered end. Correction 6: Response Letter Status: Resolved Date Status Changed: 17/08/2023 Comments: Please provide a written letter of response summarizing the changes made to address each correction comment, it must be included in your resubmittal. Failure to include a written letter of response could result in a rejection. Fees PLEASE DO NOT SUBMITANY PAYIVIENTS UNTILA COLLIER COUNTY PAYMENT SLIP IS DISTRIBUTED Total Amount Payable Online: 90.00 Deposits & Bonds Paid Fees Amount Paid Owing Date Paid ROW Residential Construction $200.00 Paid 0912512023$200.00 ROW Re-inspection - First Fail $100.00 $100.00 Paid 0512112024 ROW Re-inspection - Second Fail $150.00 $150.00 Paid 0512112024 ROW Residential/Franchise Renewal Modifications $100.00 $100.00 Paid 0512712024 ROW Re-inspection - Third Fail $200.00 $200.00 Paid 0910612024 ROW Residential/Franchise Renewal Modifications $100.00 $100.00 Paid 0910612024 ROW Re-inspection - First Fail $100.00 $100.00 Paid 111O512Q24 Outstanding Fees Amount Paid Owing Date Paid No outstanding fees Totals $e50.00 $9s0.00 $0.00 There are no deposits or bonds for this right of way, sign & well permit application --l Page 287 of 303 !nspections 815 - ROW Rough 815 - ROW Rough Failed ROW 1st 21812024 2t8t2o24 lnspector: EverildoYbaceta ((239)450-2301) Send Email Gorrections: 51112024 02t08t2024 0510112024 Correction 1: Status: Date Status Changed: Comments: lnspector Notes Carried Forward 02/08/2024 Inspector Corrections Notes : 1. Left invert 2.25 below. Must be raised to minimum requirements. 2. Left mitered end at 350/o percent. Beyond maximum allowed. Must be lowered to 33olo or 3 to 1. 3. Footers under pipe not excavated or filled in. Note: conditions will create a steep drop on right side of swale on property line Failed ROW 2nd 51112024 lnspector: Reggie Smith ((239) 2924228) Send Email lnspection 0utcome Requested Scheduled Date lnspected Outstanding 09/78/2024 Inspector Notes: Site not ready. 1. Missing Footer(s). Must contact Inspector to view exposed Footers. Right side footer dug out and not found. Review Mitered End diagram attached to Driveway Form. See photo. Left side also needs to be exposed for inspection. 2. Swales have not been graded and sodded. See Driveway Form forTop of Sod elevations. See photos. 3 Wooden form boards on Mitered Ends remain in place; needs to be removed. See photos. **xDo not reschedule 800 Final until after contacting Inspector for Footers inspection. Schedule?800 - Right-Of-Way Final lnspections Pending lnspector: Corrections: Correction 1: lnspector Notes Status: Date Status Changed: Comments: Passed 1Ol2l2O23 lnspector: LEGACY: Joseph Obert VEN ((239) 252- ) Send Email 837 - Grade lnspection 10t02t2023 I Page 288 of 303 Corrections: Correction 1: lnspector Notes Status: Resolved Date Status Changed: 05/01 /2024 Comments: Inspector Corrections Notes: 1. Left invert 2.25 below. Must be raised to minimum requirements. 2. Left mitered end at 35o/o percent. Beyond maximum allowed. Must be lowered to 33olo or 3 to 1. 3. Footers under pipe not excavated or filled in. Note: Conditions will create a steep drop on right side of swale on property line. 815 - ROW Rough Correction 2: Status: Date Status Changed: Comments: Correction 1: Statu s: Date Status Changed: Comments: lnspector Notes Outstanding 0s/24/2024 Inspector Notes: 1. Left and right mitered ends above 33o/o percent. Beyond maximum allowed. Must be lowered to between 330/o to 25o/o.3 to 1 - 4 to 1. 2. Ensure Footers under pipe are excavated and poured to code. 3. Double check Safety Zone minimum width of 24". 4. Both left and right wooden form boards are too narrow. Minimum measurements are 5'7" by 4'4". See photo. Failed ROW 3rd 61412024 61412024 lnspector: Matthew tt/oore ((239) 252-2400) Send Email Corrections: 06104t2024 lnspector Notes Resolved 06/04/2024 Inspector Notes: 1. Left and right mitered ends above 33Yo percent. Beyond maximum allowed. Must be lowered to between 33olo to 25o/o.3 to 1 - 4 to 1. 2. Ensure Footers under pipe are excavated and poured to code. 3. Double check Safety Zone minimum width of 24". 4. Both left and right wooden form boards are too narrow. Minimum measurements are 5'7" by 4'4". See photo. Page 289 of 303 Correction 2: lnspector Notes Status: Carried Forward Date Status Changed: 06/04/2024 Comments: Inspector Notes: Correction 1: Status: Date Status Changed: Comments: Correction 2: Pass with lnspector Notes Status: Resolved Date Status Changed: 09/10/2024 Comments: Pass with Inspector Notes 1. Mitered end slopes are not within the allowable 3:1to 4:1 slope 2. Must make necessary adjustments to both mitered end forms to achieve 3:1to 4:1 slope 3. Note: Both mitered end form dimensions are acceptable 4. Note: For 800 final inspection edge of pavement repairs are currently unacceptable - will need to remove cold patch and saw cut straight across entire 30' driveway apron 12" into roadway from edge of pavement and patch using hot mix asphalt - cold patch CANNOT be used in roadway 5. Note: 2'safety zone is achieved with current layout of mitered end forms - ensure 2' safety zone is kept after adjustments to mitered end forms are made to achieve 3:1to 4:l slope 815 - ROW Rough Pass with notes 911012024 lnspector: Reggie Smith ((239) 2924228) Send Email Corrections: 9t10t2024 09t10t2024 lnspector Notes Resolved 09/70/2024 Inspector Notes: 1. Mitered end slopes are not within the allowable 3:1to 4:1 slope 2. Must make necessary adjustments to both mitered end forms to achieve 3:1to 4:l slope 3. Note: Both mitered end form dimensions are acceptable 4. Note: For 800 final inspection edge of pavement repairs are currently unacceptable - will need to remove cold patch and saw cut straight across entire 30' driveway apron 12" into roadway from edge of pavement and patch using hot mix asphalt - cold patch CANNOT be used in roadway 5. Note: 2'safety zone is achieved with current layout of mitered end forms - ensure 2' safety zone is kept after adjustments to mitered end forms are made to achieve 3:1to 4:l slope 1. Mitered ends forms have acceptable slopes: L 29.4o/o R 30.0% 2. Note: For 800 final inspection edge of pavement repairs are currently unacceptable - will need to remove cold patch and saw cut straight across entire 30' driveway apron 12" into roadway from edge of pavement and patch using hot mix asphalt - cold patch CANNOT be used in roadway 3. Must clean out pipe and finish swale work for 800 Final. All inspection fees must be paid prior to Passing 800 Final. 800 - Rightof-Way Final lnspections Failed ROWlst 911812024 lnspector: Reggie Smith ((239) 2924228) Send Email 9118t2024 09118t2024 t- Page 290 of 303 Gorrections Correction 1: lnspector Notes Status: Resolved Date Status Changed: 09/t8/2024 Comments: Inspector Notes: Double check footers and Safety Zone measurements Correction 2: Status: Date Status Changed: Comments: Conditions Guidelines For Electronically Submitting Documents: Any and all Maintenance and Liability lssues Dep_aftmenl_ Development Review ExpiGtion_Datci Due Date: M iscellaneous Conditions Exprration_Datq_ Due Date: Descriotion: lnspector Notes Carried Forward 09/78/2024 Inspector Notes: Site not ready. 1. Missing Footer(s). Must contact Inspector to vlew exposed Footers. Right side footer dug out and not found. Review Mitered End diagram attached to Driveway Form. See photo. Left side also needs to be exposed for inspection. 2. swales have not been graded and sodded. See Driveway Form forTop of Sod elevations. See photos. 3 Wooden form boards on Mitered Ends remain in place; needs to be removed. See photos. xx*Do not reschedule 800 Final until after contacting Inspector for Footers inspection. Descrip:EiQ0i Any and all maintenance and liability issues including cost regarding theplacement of brick pavers in Collier County Right-of-Way stratt Oe tne futt responsibility of the permittee. Condition Typ_e: Stipulation Open Open Dep:ftmeff: Development Review Please be aware the apron width at the edge of pavement must be at a minimum of 30' Condition Typ_g; Informational Condition Status Category Miscellaneous Conditions Open DepartmeOtl Development Review Exp_uatjon_Delei Due Date: Descripion: Please be aware there must be a foot of cover over the culvert. Condition Typ_ei Informational Page 291 of 303 Dep-a-GmenI- Exprratjon_Date: Due Date: Descripljgn: Condition Ty-p_gi Open Development Review Please be aware since the work has started, it is responsibility of the owner to demolish and re-do any work necessary to meet all of Collier County ROW requirements, and to construct driveway as per Approved Driveway Form that will be provided when permit gets approved. Informational Miscellaneous Conditions Please be aware there must be a minimum of 2' safety zone from end of driveway to start of mitered end. Miscellaneous Conditions Open Development ReviewDep_a_rtmenl_ Exp-uatjpn-Datel Due Date: DescripEjonl Condition Ty_p_g : Informational lViscellaneous Conditions Open Development Review Please be aware of the current and future Collier county projects on this area: l.Golden Gate City Stormwater Drainage Improvement Southwest Quadrant, 2.Golden Gate City 15 Outfalls, 3.Golden Gate City Water Main Expansion, 4.Golden Gate City Wastewater Expansion Descriptlon: l.Golden Gate City Stormwater Drainage Improvement Southwest Quadrant, 2.This project is for the design and construction of fifteen outfall pipes and their associated inlet/outfall structures. Thls includes the surveying, access investigation, creation of real property documents, and design plans for flfteen outfall pipes and inlet/outfall structures., 3.Golden Gate City Water Main Expansion, 4.ph3: Replace Golden Gate City septic systems with sewer. Contact: Please contact collier county project Manager before construction to avoid any conflicts - Gary Putaansuu, Daniel Roman, Ben Bullert, Craig Pajer/Corinne Trtan Dep-artmen!:- Expiratisn-Datc: Due Date: Description: Condition Typ_ei Informational Request Changes to Permit Contractors or Status Dep-artmentl Expiration latei Due Date: Descrip_Ejon: Condition Ty-p_g: Open Building Review and Permitting Use the form located at https://www.collierc ov/home/showdocume nt?id= 105797&t=638403984984558370 to request permit extensions, cancellations, and changes/withdrawals of contractors, Subcontractors and Qualifiers. Instructions are provided with the form. Right-of-Way (ROW) and Well permits may only use this process for cancellations. change/withdrawal of contractor does not apply to self-issued permits. contact Building Permit Resolution Services at 239-252-2493 for assistance completing the form. Submit the form by clicking the Browse button below. Informational Page 292 of 303 Documents: Browse. ROW Permit Renewal Open Departmen!_ Building Review and Permitting Expira!!on-Da!s- Due Date: Descrip-Ejool To Extend a ROW Permit upload ROW Application and check Extension Box. Follow link to locate Right-of-Way Form; https://www.collierc gov/ho me/showpublisheddocu ment/54469/637 169203883770000 Condition Typ_si Informational Documents: Browse.. Re ceipt_2024 -O 5 -2 I _1 1 5 522.glf Extension ROW.pdf Appjeatrs! Form.pd Documents & lmages Date Uploaded File Type Name 02/08/2024 815 as built fail.JPG 02/08/2024 815 mitered end forms right,lPG 02/08/2024 815 mitered end left.JPG 815 swale condition left.lPG02/08/2024 815 swale condition right.JPG02/08/2024 03/22/2024 Expired ROW Permit Warning_(ROW - Send Permit Warning Letter).Letter 815 Fail form boards.jBgg0s/01/2024 0s/07/2024 815 as built Fail.jp-g Receiot for transaction : 2024-0459210s/2t/2024 Receipt Receipt 2024-05-21 115522.pffos/27/2024 0s/23/2024 Letter PaynnentS.lip_(PR). Receipt for transaction : 2024-0475640s/27/2024 Receipt 06/0412024 815 as built fail.PNG 06/t9/2024 Expired ROW Permit Warning_(ROW - Send permit Warning Letter)Letter 08109/2024 Ap-plreatis!-Eeo-p jf 08/72/2024 Letter Pay.nent5[p_(PR). Receipt for transaction :2024-08157409/06/2024 Receipt Expired ROW Permit Warning_(RoW - Send permit Warning Letter)0e/16/2024 Letter I n co m pletelddtgSStng Ve rif i ca ti o n - pe rm i tti n g09/78/2023 Letter 09/78/2024 800 1st Fail.jpeg 09/t8/2024 800 1st Fail.jp_sg 09/78/2024 800 missino Footer.ioeo 800 missino Footer.ioeo09/t8/2024 09/t8/2024 800 missino Footer.ioeo 09/t9/2023 Letter PayrncnlS[p_(PR). *-] -l l Page 293 of 303 Date Uploaded File Type Name 09/2s/2023 Receipt Receipt for transaction : t0/02/2023 BM set 100 00.jBg to/02/2023 BM set 100 00.jp_g t0/02/2023 BM set 100 00.jBg L0/02/2023 BM set 837 conditions .jp_g 70/0212023 BM set 837 conditions .jp_g t0/02/2023 BM set 837 conditions .jp_g to/04/2023 Applications A ppljeatjon_Eosn_( Ap p I i ca t i o n Fo rm - P re p_ared0_( Rece i ve d )-pi_0. 70l04/2023 Letter Corrections Letter EPR - Outstanding Corrections 70/04/2023 Letter (Submittal) ROW Authorization Letter (Doc2 - Prep_aree!_(Received).p_eli). 7t/0s/2024 Receipt Receipt for transaction : 2024- 100813 t7/oB/2023 Response Letter Corrections Respinse_Lettel(Resubmittal and resp_Sse_lCttel_:_Prep_Aled (Received)-p_elf). 7t/08/2023 Driveway Form Driveway_Eorm :jRRO\1120230938970 - 5254 31st pL SW, Naples*pjf 77/08/2023 Document Paver Drive Detai ls. p_glf 1.t/08/2023 Letter Right of Way_ L1_/08/2023 Pla ns ROW Plans (Resubmittal and resp_Aselet!el0_:_PrCp31qg!_-liReceived).pjl) t2/LO/2024 Extension ROW.pdf t2/L0/2024 Letter ROW Renewal Incomplete Notice Page 294 of 303 Page 295 of 303 (1) (2) (3) (4) (Ord. No. 90-105, § 4.1; Ord. No. 92-61, § 4; Ord. No. 94-34, § 4; Ord. No. 97-68, § 1, 10-28-97; Ord. No. 99-45, § 4.1—4.1.24, 6-8-99; Ord. No. 2002-21, §§ 1(4.1—4.1.24); Ord. No. 2006-46, §§ 4.1—4.1.24, 10-10-06) Sec. 22-201.1 - Misconduct—State certified contractors. The following actions by state certified contractors shall constitute misconduct and grounds for discipline pursuant to section 22-202 of this article. Failing or refusing to provide proof of public liability and property damage insurance coverage and workers compensation insurance coverage as required by Florida Statutes. Willfully violating the applicable building codes or laws of the state, city or Collier County. If the CLB finds through its public hearing process that the contractor was found by another county or municipality within the past 12 months, to have committed fraud or a willful building code violation and the CLB finds that such fraud or other willful violation would have been fraud or a willful violation if committed in Collier County or within the respective city. Fraud. (Ord. No. 94-34, § 4; Ord. No. 99-45, § 4.2—4.2.3, 6-8-99; Ord. No. 2002-21, §§ 1(4.2—4.2.3); Ord. No. 06-46, § 1(4.1.8.2)) Page 296 of 303 Page 297 of 303 Page 298 of 303 Page 299 of 303 Page 300 of 303 CONSTRUCTION STANDARDS HANDBOOK FOR WORK WITHIN THE PUBLIC RIGHT-OF-WAY COLLIER COUNTY, FLORIDA TABLE OF CONTENTS SECTION PAGE PURPOSE ii SURVEY MONUMENTS iii TERMS AND DEFINITIONS iv RELATED DOCUMENTS vi I. PERMIT REQUIREMENTS A. Application 1 B. Processing 2 C. Inspections 3 D. Blanket Permit 3 E. Exemptions from Permit Requirements 4 F. Remedies for Violation of this Ordinance 5 G. Permit and Inspection Fees 5 H. Performance Bond Requirements 5 II. CONSTRUCTION REQUIREMENTS A. Requirements for all Permits 6 B. Roadway Crossings 8 C. Attachments to Structures 9 D. Safety Requirements 10 E. Restoration Requirements 10 F. Permissible Work Hours 11 III. TURN LANES, DRIVEWAYS, ACCESS ROADS, DESIGN REQUIREMENTS A. Separate Turn Lane Requirements 12 B. Geometric Restrictions 13 C. Minimum Design Standards 14 D. Access and Site Plan Information Required 17 E. Drainage Culvert Installation 18 F. Exceptions 19 IV. MISCELLANEOUS CONSTRUCTION A. Sidewalk/Bikepath Construction 20 B. Delineation Devices 20 C. Underground Utility Accommodations 21 V. APPENDICES A. GENERAL CONDITIONS OF RIGHT OF WAY PERMITS 2 B. STANDARD FOR DESIGN AND AS-BUILT ELECTRONIC DRAWINGS 4 C. DRAWING REFERENCE FOR MINIMUM REQUIREMENTS 7 i Page 301 of 303 C. Inspections are for the purpose of correcting errors seen at the time of inspection and do not constitute acceptance for maintenance by the County, nor do they release the Permittee from liability if a failure occurs in the future. Collier County requires inspections for the following items: 1. Open-cutting of roadways. 2. Drainage culvert installations and any final swale grading. 3. Jack-and-bore construction, after opening of the jacking and receiving pits and before closure of the pits. 4. All work to be performed by means of directional boring. 5. Any other work which may disturb private property or which may require restoration of the right- of-way by the Permittee. 6. Any work which may disturb County owned or maintained landscape and irrigation within the right- of-way. 7. A county authorized inspector may, at the discretion of the Right-of-Way Section Manager or designee, impose immediate cessation of work in the right-of-way and may impose immediate corrective measures if the health, safety, or welfare of the public is determined to be at risk. The ordering of cessation of work on the basis of health, safety, or welfare shall not be cause for damages against the County or its representatives.” D. An annual “Blanket Permit” will be issued and the permit fee waived for all publicly regulated and/or franchised utility companies under any of the following conditions: 1. Where overhead lines cross the public right-of-way and there is no physical construction in the right-of-way. 2. For any construction in utility easements, unless the easement is a combination utility/drainage easement. 3. For pole replacement, except in combination utility/drainage easements. 4. When underground secondary and/or service cables are to be installed less than 300 feet in length and on road crossings where conduits or casings exist under the street. 5. Routine maintenance of permitted facilities. The Director of Road Maintenance or his designee will determine if the proposed activity is routine or not (if it is determined the activity is not routine, a ROW permit will be required). A schedule and a Blanket Permit shall be provided to the County where routine maintenance will occur. 3 Page 302 of 303 h. Site distance triangle included in all submittals, based on FDOT design standards. E. The following procedure shall be followed for the installation of drainage culvert within the public right-of- way: 1. Prior to the installation of any type of drainage culvert within the public right-of-way, a right-of-way permit shall be obtained. 2. The required culvert length, type, size, and other pertinent information including mitered end sections, concrete collars, and sod shall be shown on the approved permit. 3. The culvert grades shall be set in accordance with the approved plan and may be later modified by staff (with the ROW Permitting Section Manager’s consent) if required by practical field conditions. 4. The permittee or contractor shall place the culvert to the specified elevations and shall re-grade or re-shape the swale and road shoulders that were disturbed or damaged during construction to comply with the “General Conditions of Right-of-Way Permits” in Appendix A, and/or additional specific stipulations added to the approved permit. 5. Unless otherwise approved, a clean-out or inlet must be constructed at every common property lot line, or in accordance with FDOT requirements, whichever is less. An inlet, clean-out, or junction box shall also be required at any change of culvert size, culvert type, change of flow direction or any union of two or more culverts. The minimum inlet, clean-out, or junction box size is 24” by 36”, inside dimension. Each such inlet, clean-out, or junction box shall have a cast iron grate by United States Foundry (No. 6210) or equivalent. 6. If the swales, drainage culverts and inlets are not installed correctly, final approval will be withheld until corrected. No Certificate of Occupancy may be issued until such final approval is granted. 7. Temporary culverts must be installed within the drainageways of Collier County if construction has commenced and the approved permanent culvert is not already in place. 8. Fifteen inch diameter (unless extenuating circumstances exist as determined by the ROW Permitting Section Manager or designee) is the minimum size allowable for use where a culvert is to be connected to the County drainage system, or where a culvert is placed within the public right-of-way. 9. In cases where the culvert is associated with a driveway and is approved as part of a Building Permit, an inspection shall be made and work shall be approved prior to the Growth Management Division signing the Building Department’s “Master Control Card” to ensure that all public property has been restored to a condition satisfactory to the County. 18 Page 303 of 303