Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Agenda 10/22/2024 Item #16C 8 (Approve after the fact payment on Pay Application No. 9
10/22/2024 Item # 16.C.8 ID# 2024-778 Executive Summary Recommendation that the Board of County Commissioners, as ex-officio the Governing Board of the Collier County Water-Sewer District, approve an after-the-fact payment in the amount of $152,032.21 on Pay Application No. 9 to Mitchell & Stark Construction Company, Inc., for work completed for Change Orders No. 4, 5, 6 and 9 under Agreement No. 20-7769, “SCRWTP Reactor Tank 4,” and make a finding that this expenditure has a valid public purpose. (Project 70135) OBJECTIVE: To approve an after-the-fact payment to Mitchell & Stark Construction Company, Inc., (“M&S”) for completed work, which was short paid in the amount of $152,032.21 for Payment Application No. 9, for work that was successfully performed, and that this action is needed for successful project close out. Staff did not obtain detailed time and material cost proposals prior to issuing Work Directives 5, 6, 12, 14, 16, 18, 19, 22, and 23 for work subsequently memorialized in Change Order Nos. 4, 5, 6, and No.9 under Agreement No. 20-7769. Pursuant to CMAs, all appropriate personnel actions were taken with staff associated with this after-the-fact item. CONSIDERATIONS: On July 14, 2020 (Agenda Item 11.F), the County entered into Agreement No. 20-7769 (the “Agreement”) with M&S for the construction of Reactor Tank No. 4 at the South County Regional Water Treatment Plant (“SCRWTP”), in the amount of $3,843,000 (including a $250,000 Owner’s allowance). The Board previously approved Change Orders Nos. 4, 5 and 6 at prior meetings, on the administrative ratification sheet submitted for BCC meetings dated November 9, 2021 (Agenda Item 16.E.8), February 22, 2022 (Agenda Item 16.E.3), April 12, 2022 (Agenda Item 16.E.4) respectively, and Change Order No. 9 on December 12, 2023 (Agenda Item 16.C.6). Change Order No. 9 added $239,013.17, 14 days to the Agreement, and included the final negotiated amounts for Work Directives Nos. 5 and 12 as agreed upon during contract dispute resolution meetings held with M&S on June 14, 2023, August 23, 2023, and September 5, 2023. The $152,032.21 short pay amount is broken down as follows: (1) Change Order 9 - Work Directive No. 5 was short paid $38,176.75 due to a lack of backup documentation consisting of proposals and subcontractor and materials costs; however, this change order was a result of the contract dispute resolution settlement which was presented and approved by the Board under Agenda Item 16.C.6 on December 12, 2023. This short pay was within the Board approval of the contract dispute resolution settlement amount. (2) Change Order 9 - Work Directive No. 12 was short paid $72,164.08 because M&S and its subcontractors completed some of the work prior to staff’s issuance of the work directive, potentially worked during stop work periods, and the absence of a payment application from the subcontractor identifying the work completed; however, this change order was a result of the contract dispute resolution settlement which was presented and approved by the Board under Agenda Item 16.C.6 on December 12, 2023. This short pay was within the Board approval of the contract dispute resolution settlement amount. (3) The remaining short pay amount of $41,691.38 pertains to work completed under Change Order Nos. 4, 5, 6 and 9 that was performed without staff obtaining from M&S the required itemized estimates, material and subcontractor proposals, and where the amount exceeded the itemized estimates including labor and equipment cost overruns. Further, material credits totaling $3,956.26 proposed in CO #4 - WD #6 and CO #5 - WD #14 were not provided to the County as approved. Notwithstanding the foregoing, M&S completed all the work in a timely manner and to the satisfaction of County staff and the Engineer of Record. M&S substantially completed the work as of November 10, 2023, and the project is currently on stop work order with 3 days remaining to final completion so that the after the fact approval and the release of the withheld short pay amount related to Pay Application No. 9, as well as any paperwork necessary to close-out the project can be completed under the existing active Agreement. Staff is requesting that the Board approve the After-the-Fact memo and authorize the timely payment in the amount of $152,032.21 within Pay Application #9, as this action is needed for successful project close out. FISCAL IMPACT: Funds in the amount of $152,032.21 are encumbered in Water User Fees Capital Projects Fund Page 4199 of 7162 10/22/2024 Item # 16.C.8 ID# 2024-778 (4012), Project 70135 under Purchase Order 4500204556. GROWTH MANAGEMENT IMPACT: This project meets current Growth Management Plan standards to ensure the adequacy and availability of viable public facilities LEGAL CONSIDERATIONS: This item is approved as to form and legality and requires majority vote for Board approval. -SRT RECOMMENDATIONS: Recommendation that the Board of County Commissioners, as ex-officio the Governing Board of the Collier County Water-Sewer District, approve an after-the-fact payment in the amount of $152,032.21 on Pay Application No. 9 to Mitchell & Stark Construction Company, Inc., for work completed for Change Orders No. 4, 5, 6 and 9 under Agreement No. 20-7769, “SCRWTP Reactor Tank 4,” and make a finding that this expenditure has a valid public purpose. PREPARED BY: Alicia Abbott E.I., PMP, Project Manager III, Public Utilities Engineering & Project Management. Matthew McLean, Director, Public Utilities Engineering & Project Management. ATTACHMENTS: 1. Pay App 9 2. PO 4500204556 3. BCC Approved CO4 11-9-21 4. BCC Approved CO5 2-22-22 5. BCC Approved CO6 4-12-22 6. Exhibit F- Certificate of Substantial Completion 7. Suspension of Work 3-24-2024 8. [Linked] 20-7769 MitchellStarkConstruction_Contract_ 9. [Linked] M&S BCC Approved CO9 12-12-23 10. [Linked] Agenda Item 16.C.6 BCC Meeting - December 12th 2024 11. ATF Form SignedV4 Clerk comments AA Page 4200 of 7162 Page 4201 of 7162 EXHIBIT D (Continued)Project Name:Project Number: 70135.2Requisition No: 4500204556Bid Number: 20-7769Contract No.: 20-7769Date:Period From:Period To:PAY DESCRIPTION SCHEDULEDTOTAL Percent BALANCE ITEMVALUE COMPLETED Complete TO FINISHCONTRACT UNIT CONTRACT PREVIOUS PREVIOUS THIS PERIOD THIS PERIOD STORED AND STOREDQUANTITYTOTALAPPLICATION APPLICATION QUANTITY AMOUNT MATERIALS TO DATEQUANTITY AMOUNT1Mobilization1 ls 80,000.00 80,000.00 1.00 80,000.00 0.00 80,000.00 100% 0.000.00 0.00 0.00 0.00 0.002Demobilization 1 ls 80,000.00 80,000.00 0.00 0.90 72,000.00 72,000.00 90% 8,000.000.00 0.00 0.00 0.00 0.003Yard Piping0.00 0.00 0.00 0.00 0.003.1Potholing & Field Investigations1 ls 25,000.00 25,000.00 1.00 25,000.00 0.00 25,000.00 100% 0.003.2Tamiami Demolition1 ls 25,000.00 25,000.00 1.00 25,000.00 0.00 25,000.00 100% 0.003.38" Sludge Blowdown - Installation1 ls 55,000.00 55,000.00 1.00 55,000.00 0.00 55,000.00 100% 0.003.48" Sludge Blowdown - Pressure Testing1 ls 1,000.00 1,000.00 1.00 1,000.00 0.00 1,000.00 100% 0.003.58" Sludge Blowdown - Tie-ins1 ls 2,500.00 2,500.00 1.00 2,500.00 0.00 2,500.00 100% 0.003.68" Sludge Blowdown - Demolition1 ls 1,500.00 1,500.00 1.00 1,500.00 0.00 1,500.00 100% 0.003.74" Sludge Blowdown Tie-ins4 ea 5,000.00 20,000.00 0.00 4.00 20,000.00 20,000.00 100% 0.003.8Influent Pipe - Installation1 ls 71,500.00 71,500.00 0.90 64,350.00 0.10 7,150.00 71,500.00 100% 0.003.9Influent Pipe - Pressure Testing1 ls 1,000.00 1,000.00 1.00 1,000.00 0.00 1,000.00 100% 0.003.10Influent Pipe - Tie-in1 ls 2,500.00 2,500.00 0.00 1.00 2,500.00 2,500.00 100% 0.003.11Effluent Pipe - Installation1 ls 169,000.00 169,000.00 1.00 169,000.00 0.00 169,000.00 100% 0.003.12Effluent Pipe - Pressure Testing1 ls 1,000.00 1,000.00 0.00 1.00 1,000.00 1,000.00 100% 0.003.13Effluent Pipe - Tie-in1 ls 5,000.00 5,000.00 0.00 1.00 5,000.00 5,000.00 100% 0.003.14Overflow Pipe - Installation1 ls 32,500.00 32,500.00 1.00 32,500.00 0.00 32,500.00 100% 0.003.15Overflow Pipe - Pressure Testing1 ls 1,000.00 1,000.00 0.00 1.00 1,000.00 1,000.00 100% 0.003.16Overflow Pipe - Tie-in1 ls 1,500.00 1,500.00 0.00 1.00 1,500.00 1,500.00 100% 0.003.17Tank Drain Pipe - Under Tank1 ls 15,000.00 15,000.00 1.00 15,000.00 0.00 15,000.00 100% 0.003.18Tank Drain Pipe - Installation1 ls 52,000.00 52,000.00 1.00 52,000.00 0.00 52,000.00 100% 0.003.19Tank Drain Pipe - Pressure Testing1 ls 1,000.00 1,000.00 1.00 1,000.00 0.00 1,000.00 100% 0.003.20Tank Drain Pipe - Tie-in1 ls 2,000.00 2,000.00 0.00 1.00 2,000.00 2,000.00 100% 0.003.212" PVC Water Pipe1 ls 2,000.00 2,000.00 0.00 1.00 2,000.00 2,000.00 100% 0.003.222" Electrical Conduit Relocation1 ls 1,000.00 1,000.00 0.00 1.00 1,000.00 1,000.00 100% 0.003.23Chemical Piping1 ls 7,000.00 7,000.00 1.00 7,000.00 0.00 7,000.00 100% 0.003.24Gate Installation at Splitter Box1 ls 5,000.00 5,000.00 1.00 5,000.00 0.00 5,000.00 100% 0.000.00 0.00 0.00 0.00 0.004Clear, grubbing, and foundation preparation1 ls 28,000.00 28,000.00 1.00 28,000.00 0.00 28,000.00 100% 0.001 ls 0.00 0.00 0.00 0.00 0.005Grading and drainage0.00 0.00 0.00 0.00 0.005.1Rough Grading1 ls 40,000.00 40,000.00 1.00 40,000.00 0.00 40,000.00 100% 0.005.2Final Grading1 ls 15,000.00 15,000.00 0.75 11,250.00 0.25 3,750.00 15,000.00 100% 0.005.3Sidewalk1 ls 15,000.00 15,000.00 1.00 15,000.00 0.00 15,000.00 100% 0.005.4Preliminary Restoration/Seeding/Sod1 ls 15,000.00 15,000.00 0.50 7,500.00 0.50 7,500.00 15,000.00 100% 0.005.4Final Restoration/Cleanup1 ls 5,000.00 5,000.00 0.00 0.50 2,500.00 2,500.00 50% 2,500.000.00 0.00 0.00 0.00 0.006Lime softening reactor0.00 0.00 0.00 0.00 0.006.AStructural Components0.00 0.00 0.00 0.00 0.006.A.1Tank Slab1 ls 240,000.00 240,000.00 1.00 240,000.00 0.00 240,000.00 100% 0.006.A.2First Wall Pour1 ls 100,000.00 100,000.00 1.00 100,000.00 0.00 100,000.00 100% 0.006.A.3Second Wall Pour1 ls 100,000.00 100,000.00 1.00 100,000.00 0.00 100,000.00 100% 0.006.A.4Tank Grout1 ls 90,000.00 90,000.00 1.00 90,000.00 0.00 90,000.00 100% 0.006.A.5Tank Pedestals1 ls 7,500.00 7,500.00 1.00 7,500.00 0.00 7,500.00 100% 0.006.A.6Stair Pad1 ls 7,500.00 7,500.00 1.00 7,500.00 0.00 7,500.00 100% 0.006.A.7Leakage Testing1 ls 5,000.00 5,000.00 0.00 1.00 5,000.00 5,000.00 100% 0.006.A.8Stairs and Landings1 ls 55,000.00 55,000.00 1.00 55,000.00 0.00 55,000.00 100% 0.006.A.9Wall Pipes1 ls 15,000.00 15,000.00 1.00 15,000.00 0.00 15,000.00 100% 0.000.00 0.00 0.00 0.00 0.00WORK COMPLETEDSCHEDULE OF VALUESFebruary 2, 2024Collier County SCRWTP Reactor Tank #4November 1, 2022January 31, 2024NO WORK DURUING PERIODS WHEN THE PROJECT WAS UNDER STOP WORK ORDERPage 1 of 3Page 4202 of 7162 EXHIBIT D (Continued)Project Name:Project Number: 70135.2Requisition No: 4500204556Bid Number: 20-7769Contract No.: 20-7769Date:Period From:Period To:PAY DESCRIPTION SCHEDULEDTOTAL Percent BALANCE ITEMVALUE COMPLETED Complete TO FINISHCONTRACT UNIT CONTRACT PREVIOUS PREVIOUS THIS PERIOD THIS PERIOD STORED AND STOREDQUANTITYTOTALAPPLICATION APPLICATION QUANTITY AMOUNT MATERIALS TO DATEQUANTITY AMOUNTWORK COMPLETEDSCHEDULE OF VALUESFebruary 2, 2024Collier County SCRWTP Reactor Tank #4November 1, 2022January 31, 2024NO WORK DURUING PERIODS WHEN THE PROJECT WAS UNDER STOP WORK ORDER6.BMechanical Components0.00 0.00 0.00 0.00 0.006.B.1SUEZ Equipment1 ls 1,445,000.00 1,445,000.00 1.00 1,445,000.00 0.00 1,445,000.00 100%0.006.B.2Instruments1 ls 5,000.00 5,000.00 1.00 5,000.00 0.00 5,000.00 100% 0.006.B.3Platform and Rafter Installation1 ls 125,000.00 125,000.00 1.00 125,000.00 0.00 125,000.00 100% 0.006.B.4Launder Installation1 ls 100,000.00 100,000.00 1.00 100,000.00 0.00 100,000.00 100% 0.006.B.5Turbine Mixer Installation1 ls 5,000.00 5,000.00 1.00 5,000.00 0.00 5,000.00 100% 0.006.B.6Sludge Blowdown1 ls 10,000.00 10,000.00 1.00 10,000.00 0.00 10,000.00 100% 0.006.B.7Chemical Feed1 ls 10,000.00 10,000.00 1.00 10,000.00 0.00 10,000.00 100% 0.006.B.8Interior Piping Installation1 ls 50,000.00 50,000.00 1.00 50,000.00 0.00 50,000.00 100% 0.006.B.9Blasting of Field Welds1 ls 30,000.00 30,000.00 1.00 30,000.00 0.00 30,000.00 100% 0.000.00 0.00 0.00 0.00 0.007Protective coatings1 ls 0.00 0.00 0.00 0.00 0.007.1Exterior Tank Coating1 ls 25,000.00 25,000.00 0.00 1.00 25,000.00 25,000.00 100% 0.007.2Steel & equipment coatings1 ls 60,000.00 60,000.00 1.00 60,000.00 0.00 60,000.00 100% 0.007.3DIP coatings1 ls 23,000.00 23,000.00 0.75 17,250.00 0.25 5,750.00 23,000.00 100% 0.007.4Pipe Identification1 ls 2,000.00 2,000.00 0.00 0.50 1,000.00 1,000.00 50% 1,000.000.00 0.00 0.00 0.00 0.008Electrical1 ls 0.00 0.00 0.00 0.00 0.008.130 day Load Monitoring Study1 ls 15,000.00 15,000.00 1.00 15,000.00 0.00 15,000.00 100% 0.008.2Conduit & Boxes - Material1 ls 60,000.00 60,000.00 1.00 60,000.00 0.00 60,000.00 100% 0.008.3Wire & Cable - Material1 ls 6,000.00 6,000.00 1.00 6,000.00 0.00 6,000.00 100% 0.008.4Distribution Equipment - Material1 ls 3,000.00 3,000.00 1.00 3,000.00 0.00 3,000.00 100% 0.008.5Lighting Fixtures - Material1 ls 6,000.00 6,000.00 1.00 6,000.00 0.00 6,000.00 100% 0.008.6Conduit & Boxes - Installation1 ls 65,000.00 65,000.00 1.00 65,000.00 0.00 65,000.00 100% 0.008.7Wire & Cable - Installation1 ls 11,000.00 11,000.00 1.00 11,000.00 0.00 11,000.00 100% 0.008.8Distribution Equipment - Installation1 ls 12,000.00 12,000.00 1.00 12,000.00 0.00 12,000.00 100% 0.008.9Lighting Fixtures - Installation1 ls 2,000.00 2,000.00 1.00 2,000.00 0.00 2,000.00 100% 0.000.00 0.00 0.00 0.00 0.009Instrumentation1 ls 30,000.00 30,000.00 1.00 30,000.00 0.00 30,000.00 100% 0.0010Calibration of instruments1 ls 5,000.00 5,000.00 1.00 5,000.00 0.00 5,000.00 100% 0.0011Startup and training1 ls 30,000.00 30,000.00 0.40 12,000.00 0.60 18,000.00 30,000.00 100% 0.0012Disinfection1 ls 20,000.00 20,000.00 0.50 10,000.00 0.50 10,000.00 20,000.00 100% 0.0013Commissioning1 ls 35,000.00 35,000.00 0.00 1.00 35,000.00 35,000.00 100% 0.0014Record drawings1 ls 5,000.00 5,000.00 0.00 1.00 5,000.00 5,000.00 100% 0.001 ls 0.00 0.00 0.00 0.00 0.001 ls 0.00 0.00 0.00 0.00 0.001 ls 0.00 0.00 0.00 0.00 0.00SUBTOTAL3,593,000.00 3,347,850.00 233,650.00 3,581,500.00 11,500.001 ls 0.00 0.00 0.00 0.00 0.00Owner's Allowance1 ls 0.00 0.00 0.00 0.00 0.00 0.00CO#2 - Work Directive #21 ls 6,354.57 6,354.57 1.00 6,354.57 0.00 6,354.57 0.00CO#2 - Work Directive #31 ls 26,108.12 26,108.12 0.9996181265 26,098.15 0.00 26,098.15 9.97CO#2 - Work Directive #81 ls 6,734.70 6,734.70 0.8767576878 5,904.70 0.00 5,904.70 830.00CO#3 - Field Trailer1 ls 20,465.58 20,465.58 0.2924192718 5,984.53 0.6467033917 13,235.16 19,219.69 1,245.89CO#4 - Work Directive #51 ls 53,650.00 53,650.00 0.00 0.9998115564 53,639.89 53,639.89 10.11CO#4 - Work Directive #61 ls 21,911.13 21,911.13 0.00 0.5978673852 13,099.95 13,099.95 8,811.18CO#4 - Work Directive #91 ls 4,714.00 4,714.00 0.00 0.9018604158 4,251.37 4,251.37 462.63CO#4 - Work Directive #101 ls 5,065.00 5,065.00 0.00 0.5083909181 2,575.00 2,575.00 2,490.00CO#5 - Work Directive #131 ls 146.98 146.98 0.00 0.00 0.00 146.98CO#5 - Work Directive #141 ls 17,173.44 17,173.44 0.00 0.1718490879 2,951.24 2,951.24 14,222.20CO#5 - Work Directive #151 ls 27,314.68 27,314.68 0.5194422926 14,188.40 0.00 14,188.40 13,126.28CO#6 - Work Directive #71 ls -5,287.65(5,287.65)0.00 1.00 (5,287.65) (5,287.65) 0.00Page 2 of 3Page 4203 of 7162 EXHIBIT D (Continued)Project Name:Project Number: 70135.2Requisition No: 4500204556Bid Number: 20-7769Contract No.: 20-7769Date:Period From:Period To:PAY DESCRIPTION SCHEDULEDTOTAL Percent BALANCE ITEMVALUE COMPLETED Complete TO FINISHCONTRACT UNIT CONTRACT PREVIOUS PREVIOUS THIS PERIOD THIS PERIOD STORED AND STOREDQUANTITYTOTALAPPLICATION APPLICATION QUANTITY AMOUNT MATERIALS TO DATEQUANTITY AMOUNTWORK COMPLETEDSCHEDULE OF VALUESFebruary 2, 2024Collier County SCRWTP Reactor Tank #4November 1, 2022January 31, 2024NO WORK DURUING PERIODS WHEN THE PROJECT WAS UNDER STOP WORK ORDERCO#6 - Work Directive #161 ls 14,178.98 14,178.98 0.00 1.00 14,178.98 14,178.98 0.00CO#8 - Field Trailer1 ls 7,885.80 7,885.80 0.00 0.990347206 7,809.68 7,809.68 76.12CO#9 - Work Directive # 51 ls 40,103.00 40,103.00 0.00 1.00 40,103.00 40,103.00 0.00CO#9 - Work Directive #121 ls 143,928.87 143,928.87 0.00 1.00 143,928.87 143,928.87 0.00CO#9 - Work Directive #181 ls 5,918.75 5,918.75 0.00 1.00 5,918.75 5,918.75 0.00CO#9 - Work Directive #191 ls 1,282.36 1,282.36 0.00 1.00 1,282.36 1,282.36 0.00CO#9 - Work Directive #201 ls 2,507.50 2,507.50 0.00 1.00 2,507.50 2,507.50 0.00CO#9 - Work Directive #211 ls 3,001.61 3,001.61 0.00 1.00 3,001.61 3,001.61 0.00CO#9 - Work Directive #221 ls 19,268.32 19,268.32 0.00 1.00 19,268.32 19,268.32 0.00CO#9 - Work Directive #231 ls 66,587.43 66,587.43 0.00 1.00 66,587.43 66,587.43 0.001 ls 0.00 0.00 0.00 0.00 0.001 ls 0.00 0.00 0.00 0.00 0.001 ls 0.00 0.00 0.00 0.00 0.000.00 0.00 0.00 0.00 0.00TOTAL4,082,013.17 3,406,380.35 622,701.46 0.00 4,029,081.81 52,931.36Page 3 of 3Page 4204 of 7162 Page 4205 of 7162 Page 4206 of 7162 Page 4207 of 7162 Page 4208 of 7162 Page 4209 of 7162 Page 4210 of 7162 Page 4211 of 7162 Page 4212 of 7162 Page 4213 of 7162 Page 4214 of 7162 Page 4215 of 7162 Page 4216 of 7162 Page 4217 of 7162 Page 4218 of 7162 Page 4219 of 7162 Page 4220 of 7162 Page 4221 of 7162 Page 4222 of 7162 Page 4223 of 7162 Page 4224 of 7162 Page 4225 of 7162 Page 4226 of 7162 Page 4227 of 7162 Page 4228 of 7162 Page 4229 of 7162 Page 4230 of 7162 Page 4231 of 7162 Page 4232 of 7162 Page 4233 of 7162 Page 4234 of 7162 Page 4235 of 7162 Page 4236 of 7162 Page 4237 of 7162 Page 4238 of 7162 Page 4239 of 7162 Page 4240 of 7162 Page 4241 of 7162 Page 4242 of 7162 Page 4243 of 7162 Page 4244 of 7162 Page 4245 of 7162 March 22, 2024 Mr. Mike Westhafer Mitchell & Stark Construction Company 9009 High Cotton Lane Fort Myers, Florida 33905 RE: Notice to Suspend Work Contract No. 20-7769 SCRWTP Reactor Tank # 4 - Construction Purchase Order #4500204556 Collier County Project No. 70135.2 Dear Mr. Westhafer: Effective on March 24, 2024, please be notified that the above referenced contract is suspended until further notice. The current final completion date is March 27, 2024. Therefore, when the suspension is lifted, there will be 3 days remaining to achieve final completion. Please submit your invoices for work completed to date within thirty (30) days after issuance of this letter. If you have any questions, please do not hesitate to contact me. Sincerely, Alicia Abbott, E.I., PMP, Project Manager III C: Procurement Services Page 4246 of 7162 CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with Mitchell & Stark Construction Co., Inc. ("Contractor") of 6001 Shirley Street, Naples, FL 34109, a Corporation, authorized to do business in the State of Florida, to perform all work ("Work") in connection with South County Regional Water Treatment Plant (SCRWTP) Reactor Tank #4, Invitation to Bid No. 20-7769 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Carollo Engineers, Inc., the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement' and sometimes as the Contract'). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount'), in accordance with the terms of this Agreement: Three Million Eight Hundred Forty -Three Thousand Dollars and 00/100 3,843,000.00 ) Section 4. Bonds. A. If applicable, the Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit B-1 and B-2, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www,fms.treas,gov/c570/c570.html#certified. Should the Contract Amount be less 1 M1kt) Construction Services Agreement: Revised 072118 (v6) , Page 4247 of 7162 than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liauidated Damaaes. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within Three Hundred (300) calendar days from the Commencement Date (herein Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within Thirty (30) calendar days after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, Two Thousand Five Hundred Seventy -Nine Dollars ($2,579.00) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion. The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday 2 Construction Services Agreement: Revised 072118 (v6) Page 4248 of 7162 or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non -delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed upon, attached hereto and made a part of this Agreement for Solicitation 20-7769 "South County Regional Water Treatment Plant (SCRWTP) Reactor Tank #4. Exhibit A-1: Contractor's Bid Schedule Exhibit A-2: Contractor's Bid Submittal Forms and Addendums Exhibit A-3: Contractor's List of Key Personnel Exhibit B-1: Payment Bond Forms Not Applicable Exhibit B-2: Performance Bond Forms Not Applicable Exhibit B-3: Insurance Requirements Exhibit C: Release and Affidavit Form Exhibit D: Contractor Application for Payment Form 3 CpU Construction Services Agreement: Revised 072118 (v6) Page 4249 of 7162 Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions ® Applicable Not Applicable The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 20-7769 "South County Regional Water Treatment Plant SCRWTP) Reactor Tank #4. The complete contract documents, including Addendum with attachments, are available on the County's on-line bidding system: https://www.bidsync.com/bidsync-cas/, which the parties agree comprise the final integrated agreement executed by the parties. Sections corresponding to any checked box ( ® ) expressly apply to the terms of this Agreement and are available through the County's on-line bidding. Exhibit J: Technical Specifications Exhibit K: Permits Exhibit L: Standard Details Exhibit M: Plans and Specifications prepared by Carollo Engineers, Inc. Exhibit N: Environmental Health and Safety Requirements for Construction Projects Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, FL c/o Public Utilities Engineering & Project Management Division 3339 Tamiami Trail East, Suite 303 Naples, Florida 34112-5361 Attn: Alicia Abbott, Project Manager Phone: (239) 252-5344 Email: Alicia.Abbottp_colliercountyfl.gov B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Mitchell & Stark Construction Co., Inc. 6001 Shirley Street Naples, Florida 34109 Attn: Michael P. Westhafer, Vice President Phone: (239) 597-2165 Email: mwesthafer(o-)mitchellstark.com C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. a C fo Construction Services Agreement: Revised 072118 (v6) Page 4250 of 7162 Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)( a) of the Florida Statutes which read as follows: A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreement. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. 5 CA Construction Services Agreement: Revised 072118 (v6) Page 4251 of 7162 Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. 6 010 Construction Services Agreement: Revised 072118 (v6) Page 4252 of 7162 IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s) indicated below. TWO WITNESS FIRST WITNESS Print Naphe SECOND WITNESS r Print Name Date: - ATTEST: CrystaL. K..Kipz0k, Perk of Courts Qom, rller i toG Attes: sto.G a s as t F m andLegality: IV County Attorney Print CONTRACTOR: Mitchell & Stark Construction Co., Inc. By: E 11 Print Name and Title 0 Date 7 tt I`Ll' BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY FLORIDA BY: JL Burt L. Saunders, Chairman 0— Construction Services Agreement: Revised 072118 (v6) ' Page 4253 of 7162 EXHIBIT A-1: CONTRACTOR'S BID SCHEDULE FOLLOWING THIS PAGE) 8 Construction Services Agreement: Revised 072118 (v6) OC Page 4254 of 7162 Solicitation # 20t7769 Solicitation Title SCWTP Reactor Tank #4 Bid Due Date June 4, 2020 @ 3:00 PM BID SCHEDULE Collier County Public Utilities Department Project No. 70135 PROJECT: South County Regional Water Treatment Plant Reactor Tank Number Four iTEM I DESCRIPTION I QUANTITY I UNIT LABEL I TOTAL BASE BID; Includes all items described in the Summary of Work and as shown in the attached Drawings and Specifications with no substitutions or limitations. 1 M BIUZATION (as specified in Section 01,90 90) Not to exceed 3% of the Contract Price per Section 01 20 00 1 LUMP SUM 80,000,00 2 DEMOBILI7AT1QN (as specified in Section 01_20 00,) NW Less than 2% of the Contract Price per Section 01 20 00, 1 LUMP SUM 80,000.00 3 Yard piping 1 LUMP SUM 500,000.00 4 Clear, grubbing, and foundation preparation 1 LUMP SUM 28,000.00 5 Grading and drainage 1 LUMP SUM 90.000.00 6 Lime soft ning reactor 1 6.A Structural Components 1 LUMP SUM 620,000.00 6.B Mechanical Components • Equipment and installation 1 UMP SUM 1,780,000.00 7 Protective coatings 1 i LUMP SUM 110,000,00 8 Electrical 1 LUMP SUM 180,000.00 9 Instrumentation 1 LUMP SUM 30,000.00 10 Calibration of instruments 1 LUMP SUM 5,000.00 11 Startup and trainin 1 LUMP SUM 30,000.00 12 Disinfection 1 LUMP SUM 20,000.00 13 Commissioning 1 LUMP SUM 35,000.00 14 Record drawings 1 LUMP SUM 5,000.00 W___................_ ._.... TRA V EWORK-S r—TTFIf 15 Owner's Allowance (Time & Materials)" $ 1 MATERIAL 250,000 TOTAL Btt3 PRICE 1 $3,$43,000.00 Owners Allowance - for Owners Use as Directed. This Allowance will be used only at the Owner's direction to accomplish work due to unforeseen conditions and/or as directed by the Owner, inclusion of the Allowance as part of the Contract Price is not a guarantee that the Contractor will be paid any portion or the full amount of the Allowance. Expenditures of Owners Allowance will be made through Change Order with proper documentation of Time and Materials supporting the change." NOTES; 1) Failure of the bidder to provide information in ALL of the boxes above may result in the bid proposal being considered non -responsive and rejection of the bid proposal Zero (0) is considered a valid response, but a blank is riot. 0 Page 4255 of 7162 EXHIBIT A-2: CONTRACTOR'S BID SUBMITTAL FORMS AND ADDENDUM FOLLOWING THIS PAGE) 9 Construction Services Agreement: Revised 072118 (v6) Page 4256 of 7162 C: d h r COU ty Acirniristrabve Services DVisK>n Procumesrk nt Serwx—, Date: May 8, 2020 Email: Jini.l~lanagan@colliercountyfl.gov Telephone: (239) 252-8946 Addendum #1 Frorn: Jim Flanagan, Procurement Mangler To: Interested Bidders Subject: Addendum #1 Solicitation 20-7769 SC.:RW'i'P Reactor "Tank #4 flee following clarifications are issued as an addendum identifying the following clarification to the scope of work, changes, deletions, or additions to the original solicitation document for the referenced solicitation: Change 1. Change pre -bid site visit schedule and procedure/scheduling in compliance with COVID 19 1 im itations Remove Instead: In compliance with COVID-19 and CDC recommendations, the non -mandatory site visit will be pre -scheduled for specific times between 9:00 and 11:00a.m. on Thursday May 14 2020, at the ropsect site - SCRWTP, 3851 City Gate Drive, Naples, FL 34117. Contractors are limited to one or two persons only, with a maximum of 4 persons (two contracting firms) per time slot (half an hour increments). Contractors should indicate their interest for a site visit during the non —mandatary pre -bid conference call, and an assigned time will be scheduled for each interested contractor for May 14. Social Distancing practices relative to the COVID-19 pandernic will be imposed during the site visit. The use of a protective mask on all site visitors is encouraged. We would like to start with 2 contractors per time slot, then if there are more than 8 contractors interested in a site visit, a third contractor can be added into each time slot. if there are more than 12 contractors, then another time slot will be added for 11:00 am. Attached Site Visit Seliedule 'Template for reference only If you require additional information please post a question on our Bid Sync (www.bids nc.corn) bidding platform under the solicitation for this protect. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6J4120 Signature) Date Mitchell & Stark Construction Company, Inc. Name of 1" irm) 0 Page 4257 of 7162 00fher C014-11ty Email: Jini.Flatiagan((colliercountyfl.gov Telephone: 239.252.8946AdninistraweSer,ces Dimsion ocuiement ADDENDUM # 2 Date: May 18,2020 Jim Flanagan, Procurement Manager To: Interested Bidders Subject: Addendum # 2 - 20-7769 SCRWIT Reactor Tank #4 This Addendum has been issued for the following items identifying clarifications, changes, deletions, and/or additions to the scope of work, solicitation documents and./or bid schedule for the above reflerenced solicitation: ADDITION: 1. The FDOT Standard Specifications Liquidated Damages schedule will go into effect July 2020. As such, Liquidated Damages for this solicitation is revised from per calendar day to TwO Thousand Five Hundred S,vent Nine dollars t$2,00 per calendar day Reference 20-7769 -, Addendum #1 - l"IX)TI-iquidated Damages rev 07-2020, attached 2. NOTICE: BID OPENING CHANGE OF VENUE: Bid Opening to be held in -person at Procurement Services Conference Room A, 3295 Tamiami Trail East, Naples FL. 34112, and will not be accessible on Procurement Bridge phone. Social Distancing practices and precautions relative to the COVID-19 pandemic will be imposed during this Public meeting. 3. Bidders are reminded to provide all required bid forms and attachments. Reference Bidders Checklist provided in the Solicitation document 4. 20-7769 Pre -Bid meeting Minutes and Sign -in Sheets, attached If you require additional information please post a question on our Bid Sync (w•ww.bLd,- ,,.ygc,co.m) bidding platform under the solicitation For this prqject. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. Signature) Mitchell & Stark Construction Company, Inc. Name of Finn) 6/4/20 Date 0 Page 4258 of 7162 C40' e-r county AdmirisMla ve Services Divsicri Procuremerrt Services Email: Jim.Flanagan(?colliereotirrtyfl.gov Telephone: 239.252.8946 ADDENDUM # 3 Date: May 28. 2020 From: Jim Flanagan, Procurement Manager To: Interested Bidders Subject: Addendum # 3 - 20-7769 SCRWTP Reactor'Tank #4 This Addendum has been issued for the following items identifying clarifications, changes, deletions, and/or additions to the scope of work, solicitation documents and/or bid schedule for the above referenced solicitation: ADDITION: 1.. The FDOT Standard Specifications Liquidated Damages schedule will go into effect July 2020. As such, Liquidated Damages for this solicitation is revised from per calendar day to Two Thousand Five Hundred Seveq!y Nine dolii rs ( .:5. 9,(3tij per calendar day. Reference 20-7769 - Addendum #3 - FDOT Liquidated Damages rev 07-2020,, attached Regarding Bid Opening: ALL RIDS SMALL BE SUBMITTED ELECTRONICALLY ON-LINE VIA BIDSYNC If you desire to attend the Bid Opening meeting to observe the opening of the Electronic Bids as submitted on BidSync, it will be held at Procurement Services Conference Room A, 3295 Tamiami Trail East, Naples FL 34112, and will not be accessible on Procurement Bridge phone. Social Distancing practices and precautions relative to the COVID-19 pandemic will be imposed during this Public meeting. AGAIN, PLEASE NOTE: ALL BIDS SHALL BE SUBMITTED ELECTRONICALLY ON-LINE VIA BIDSYNC 3. Bidders are reminded to provide all required bid forms and attachments. Reference Bidders Checklist provided in the Solicitation document. 4. FORM 5 SHOULD PROVIDE REFERENCES FOR "TANK CONSTRUCTION OR SIMILAR PROJECTS WITHIN THE LAST TEN (10) YEARS AS A JUDC.3E OF ITS EXPERIENCE, SKILL. AND BUSINESS STANDING AND OF ITS ABILITY TO CONDUCT THE WORK AS COMPLETELEY AND AS RAPIDLY AS REQURI D UNDER THE TERMS OFTHE AGREEMENT. Referencing Minimum Qualifications of Bidders per Supplemental Terms and Conditions: Bidders/ Contractors must show experience and successful completion of projects with the construction of Lime Softening Water Treatment Plants (including Clarifiers/Reactor Tanks), and water bearing concrete structures, or similar projects.. A. Minimum qualification requirements for General Contractors shall include completion of at least 3 projects in the past ten (10) years, which meet the following criteria: 1. Minimum contract value of $1,500,000. 2. Water or wastewater treatment plant projects. The scope of work for these reference projects shall include either water and/or wastewater clarifiers (including mechanisms with rotating assemblies) in circular reinforced concrete water retaining structures of at the least the size indicated on the drawings. Two Reference projects shall be in the State of Florida. The third reference project shall be in Florida or a southeast coastal area with atmospheric requirements similar to those of the project 0 Page 4259 of 7162 site (including but not limited to environmental conditions, humidity, weather, groundwater table, wind, and any other specific criteria as outlined in the Florida Building Code). 3. Retrofit, rehabilitation, or improvements completed to an operating water or wastewater facility without unreasonable disruptions to service due to Contractor's actions or failure to act. 4. Work including water retaining structures, gravity and pressure piping systems, site work, structural, mechanical, electrical, and instrumentation work of similar type, size, and complexity, 5. Projects completed and operating to the satisfaction of Owner (to be verified by calling references). 6. Projects completed on time. 7. Projects completed within budget without unreasonable claims or excessive change orders. 8. Proposed project manager and superintendent shall personally have completed projects to meet all criteria listed above as well. B. Any subcontractors selected by Contractor shall have equivalent experience for the trade in which the work will be performed (exclusive of dollar value noted). BIDDERS TO PROVIDE EVIDENCE OF THE ABOVE ON FORM 5 - STATEMENT OF EXPERIENCE OF BIDDER AS FOUND IN THE SOLICITATION DOCUMENT USE ADDITIONAL COPIES OF FORM 5 IF NECESSARY A. Contractor to provide a matrix. 'rhe matrix should include each of these requirements (shown on one axis), and a list of projects (on the other axis). A checkmark (Yes,No) to be used to indicate if the contractor has experience on that regiment for each project listed." 5. 20-7769 Pre -Bid meeting Minutes and Sign -in Sheets, attached SUPPI,EM ENT'Al.. INFORMATION 0. The Subsurface Soil Exploration Analysis and Recommendations - Proposed Reactor'1'ank 4 _. South County Regional Water'l'reatment Plant - Naples - Collier County Florida by Ardaman & Associates, lnc. is attached. 7. 20-7769 - Consolidated Bid Questions and Answers attached. 8. 20-7769 - SUEZ Spec Review Comments. SUEZ provided comments during the bid period to the County which were reviewed by the Engineer and those comments and responses are attached. CONTRACTDOCUMENT'S - SPECIFICATIONS 9. Section 01 11 00 _ Summary of Work Refer to Paragraph 1.07, Qualification of Bidders, and replace it with the following new Paragraph 1.07: 1. Ci7 QUALIFICATIONS OF BIDI)FRS A. Minimum qualification requirements for General Contractors shall include completion of at least 3 projects in the past ten (10) years, which meet the following criteria: Minimurn contract value of $1,500,000, Water or wastewater treatment plant projects. 'i'he scope of work for these reference projects shall include either water and/or wastewater clarifiers including mechanisms with rotating assemblies) in circular reinforced concrete water retaining structures of at least the size indicated on the drawings. ' Two Reference projects shall be in the State of Florida. 1'he third C * it Page 4260 of 7162 reference preject shall be in Florida or a southeast coastal area with atmospheric requirements similar to those of the project site (including but not limited to environmental conditions, humidity, weather, groundwater table, wind, and any other specific criteria as outlined in the Florida Building Code). I Retrofit, rehabilitation, or improvements completed to an operating water or wastewater facility without unreasonable disruptions to service due to Contractor's actions or failure to act. 4. Work including water retaining structures, gravity and pressure piping systems, site work, structural, mechanical, electrical, and instrumentation work of similar type, size, and complexity. S. Projects completed and operating to the satisfaction of Owner (to be verified by calling references). 6. Projects completed on time. 7. Projects completed within budget without unreasonable claims or excessive change orders. 8. Proposed project manager and superintendent shall personally have completed projects to meet all criteria listed above as well. B. Any subcontractors selected by Contractor shall have equivalent experience for the trade in which the work will be performed (exclusive of dollar value noted), C. Contractor to provide a matrix. The matrix should include each of these requirements (shown on one axis), and a list of projects (oil the other axis). A checkmark (Yes/No) to be used to indicate if the contractor has experience on that regiment for each project listed." 10. Section 46 43 54 - Solids Contact Clarifier Equipment Refer to Paragraph 1.04.1), the line titled *'Minimum Detention Tinic in the Reaction Zone at Design 1'reatnient Flow", replace the phrase ->30 minutes" with the phrase ">20 minutes," Refer to Paragraph 1.04.D, the line titled "Weir Loading Rate-, replace the phrase "< 20 gpni!ft2'* with the phrase ->20 gpin/ft." Refer to Paragraph 2.05.13.1, replace the digit "o)"' with the digits "14-. Refer to Paragraph 3.01.A.1, delete this Paragraph and replace the following new paragraph: "I. Field welding is permitted only where indicated on the drawings, this specification, or otherwise approved by the Engineer.** Add new Paraph 2.09.G with the following text: 6. ATyp c "F" valve shall also be provided for the bottom flush assembly as indicate(] on theType Drawings." Add new Paragraph 2.17 with the following text: 2.17 Solenoid Valves A. 3-way solenoid valves: 1 Manufacturers: One of the following or equal: a. ASCO (Automatic Switch Co.), Series 832. B. Design: 1. Valves: Suitable for service under the following conditions: 0 Page 4261 of 7162 a. Fluid water. b. Temperature of fluid: 75 degrees Fahrenheit. C. Piping test pressure: 150 pounds per square inch gauge. 2. Unless otherwise indicated on the Drawings, provide valves that meet the following requirements: a. Minimum NFMA Type 4 enclosure. b. 120 VAC operation, C. Suitable for use as indicated on the Drawings. d. Minimum Class Fcoil insulation. I Famish with openings of size equal to or larger than the nominal size designation of the valve, 4. Furnish with manual/bypass operators. C. Materials: 1. Body: Brass or bronze. 2. Seats: Resilient material. CON'rRACTDOCUMENTS - DRAWINGS: 11. Drawing OOCOI - Bid Set - Site Replace Drawing OOCO I with the attached, revised drawing OOCO I marked Addendum 3. 12. Drawing 000O2 - Bid Set - Yard Piping Replace Drawing O00O2 with the attached, revised drawing O00O2 marked Addendum 3, 13, Drawing OOMOI -Reactor 4 Upper Plan Replace Drawing OOMOI with the attached, revised drawing OOMOI marked Addendum 3. 14. Drawing OOM03 - Reactor 4 Section Replace Drawing OOM03 with the attached, revised drawing OOM03 marked Addendum 3, 15. Drawing OOTMOI -- Mechanical Typical Details Replace Drawing OOTMOI with the attached, revised drawing OOTMOI marked Addendum 3. Ifyou require additional information please post a question on our Bid Si'Wc (wmv.bid.vvnC.(!0 bidding plulfin-in under the Solicitenionftw this project, Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6;14,'2(') Signature) Datc NI i(CIICII ''. S(M k 0',,dkl'WAWII COi, 111C. Name of Firm) ONO Page 4262 of 7162 coiker C014-nty Administrative Services Division Procurement Servr,,es Email: Jim.Flanagan( colliercountyfl.gov Telephone: 239.252.8946 ADDENDUM # 4 Date: June 02, 2020 From: Jim Flanagan, Procurement Manager To: Interested Bidders Subject- Addendum # 4 20-7769 SCRWTP Reactor Tank #4 This Addendum has been issued for the following items identifying clarifications, changes, deletions, and/or additions to the scope of work, solicitation documents and/or bid schedule for the above referenced solicitation: CONTRACT I)OCUMENTS— SPECIFICATIONS: Section 46 43 54 — Solids Contact Clarifier Equipment Refer to Paragraph I .04.G. I. a. I), the line titled "Total Hardness", replace the digits *3 78" with the digits 323,- FORM 5 SHOULD PROVIDE REFERENCES FOR TANK CONSTRUCTION OR SIMILAR PROJECTS WITHIN THE LAST TEN (10) YEARS AS A JUDGE OF ITS EXPERIENCE, SKILL AND BUSINESS STANDING AND OF ITS ABIL.ITY TO CONDUCTTHE WORK AS COMPL. ETELEY AND AS RAPIDLY AS REQURED UNDER. THE TERMS OF -11413 AGREEMENT, Referencing Minimum Qualifications of Bidders per Supplemental "Penns and Conditions. BIDDERS TO PROVIDE EVIDENCE OF THE ABOVE ON FORM 5 — STATEMENT OF EXPERIENCE OF BIDDER AS FOUND IN THE SOLICITATION DOCUMENT USE ADDITIONAL COPIES OF FORM 5 IF NECESSARY Contractor to provide a matrix. The matrix should include each of these requirements (shown on one axis), and list of projects (on the other axis). A checkmark (Yes/No) to be used to indicate if the contractor has experience on that regiment for each project listed." Bidders are reminded to provide all required bid forms and attachments. Reference Bidders Checklist provided in the Solicitation document. Bid Due is unchanged: Bids due on-line in BidSync no later than Thursday May 4..2020 (w 3:00pat Ifyou require additional inft)rmationplease post a question on our did Sync (Wvq.%h...sv.n.C..C.o.m bidding undei the Solicitationfi)r this protect. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 614/ 20 Signature) Mitchell & Stark Construction Company, .Inc. Narne of Finn) Date 0 Page 4263 of 7162 Director, Procurement Services Division FORM I - BID RESPONSE FORM BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA South County Regional Wat.er'Freatment Plant (,SC.'RWTP) Reactor `Wank #4 BID NO.20-7769 Dull Name of Main Business Address Mitchell & Stark Construction Company, Inc. 6001 Shirley Street, Naples. FL. 34109 Place of Business Same Telephone No. 239- 597-2165 Fax No State Contractor's License # C GC058926 239- 332-2819 State of Florida Certificate of Authority Document Number 845897 Federal Tax Identification Number35- 0964820 DUNS h C'CR _ Cage Code To: BOARD OF COUNTY COMMISSIONERS OFF COLLIER COUNTY, FLORIDA hereinafter called the Owner) The undersigned, as Bidder declares that the only person or parties interested in this Bid as principals are those named herein, that this Bid is submitted without collusion with any other person, firm or corporation; that it has carefully examined the location of the proposed Work, the proposed form of Aereement and all other Contract Documents and Bonds. and the Contract Drawings and Specifications. Bidder proposes. and agrees if this Bid is accepted, Bidder will execute the Agreement included in the Bidding Documents.. to provide all necessary machinery, tools, apparatus and other means of construction, including utility and tratisportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract, and to do all other thinks required of the Contractor by the Contract Documents, and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points, and in the case where further decimal points are inadvertently provided, rounding, to two decimal points will be conducted by Procurement Services Division staff, Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement forth attached to the Bidding documents within ten (10) calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents. The bid security attached is to become the property of the Owner in the event the Agreement, Insurance Certificates and Bonds are not executed and delivered to Owner within the time above set forth, as liquidated damages, for the delay and additional expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period, In the event of such failure, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it faits to execute and deliver the Agreement, Insurance Certificates, and Bonds as required hereunder. The Constttaction Solicitation Doc rev 02-21-20 C to Page 4264 of 7162 Successful Bidder hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty. which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely manner. Upon receipt ol"the signed and approved agreement and Purchase Order, the undersigned proposes to commence work at the site within five (5) calendar days from the commencement date stipulated in the written Notice to Proceed unless the Project Manager, in writing, Subsequently notifies the Contractor of a modified (later) commencement dale. The undersigned further agrees to substantially complete all work covered by this Bid within Three 11undred (300) consecutive calendar days, computed by excluding the commencement date and including the last day of'such period, and to be fully completed to the point of final acceptance by the Owner within Thirty (30) consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. Acceptance and acknowledged by an Authorize Agent Signature: Title: Vice President 6/4/20 Date: Construction Solicitation Doc rev 02-21-20 OCINO Page 4265 of 7162 FORM 2 -CONTRACTOR'S KEY PERSONNEL ASSIGNED TO TUE PROJECT South County Regional Water Treatment Plant (SCRW`TP) Reactor Tank 44 Bid No. 20-7769 Nam Brandon Tripp Josh Peterson Construction Solicitation Doc rev 02-21-20 Personnel Cq!Moa, Construction Superintendent ProJect KUnager Page 4266 of 7162 FORM 3 - MATERIAL MANUFACTURERS THIS FORM MUST BE COMPLETED OR BID SHALL BE DEEMED NON -RESPONSIVE All Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this Bid specifications, including; compliance with Florida Statute 255.20 to provide lumber, timber and other forest products produced and manufactured in the State of Florida as long, as the price, fitness and quality are equal. Exceptions (when equals are acceptable) may be requested by completing the ;Material Manufacturer Exception List below. if an exception for a manufacturer and>or material is proposed and listed below and is not approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in the specification. Acceptance of this form does not constitute acceptance of material proposed on this list. Complete and sign section A OR B. Section A (Acceptance of all manufactures and materials in Bid specifications) On behalf of my firm, I confirm that we will use all manufacturers and materials as specifically outlined in the Bid specifications. Company: Mitchell & Stark Construction Company, Inc. Signature: '"'" "` W...... Date: 6/4120 Section B (Exception requested to Bid specifications manufacturers and materials) EXCEPTION IGMATF.RIAL EXCEPTIC N .MANUFACTURER 4, Please insert additional pages as necessary. Company: Mitchell & Stark Construction Company, Inc. Signature'_ Date 6/4/20 Construction Solicitation Doc rev 02-21-20 0 Page 4267 of 7162 FORM 4 - LISTOF MAJOR SUBCONTRACTORS THIS t,isT MUST BE COMPLETED OR BID MAYBE DEEMED NON -RESPONSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories outlined in the requirements of the )aid specifications. The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the major categories listed herein are "qualified" (as defined in Ordinance 2017-08 and Section 15 of Instructions to Bidders) and meet all legal requirements applicable to and necessitated by the Contract Documents, including, but not limited to proper licenses, certifications. registrations and insurance coverage. The Owner reserves the right to disqualify any Bidder who includes non -compliant or non -qualified Subcontractors in its bid offer. Further. the Owner may direct the Successful Bidder to remove/replace any Subcontractor, at no additional cost to Owner, which is found to be non -compliant with this requirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents, the Successful Bidder shall identify all Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified as noted above. Major Category of Work Subcontractor and Address I , _ Concrete 1 c , r: >'t 2. Reactor Structural Components I r. Ise 1r 1, 3. Reactor Mechanical Components_ 4, Protective Coatings 5, Sitework fol,1 I6. Underground Utilities 1 7 'tlr_ 1_ --, T Mechanical Je,Ir" ! r , 8 Electrical ia;f d" 9. Identify other subcontractors that represent more than 10% of price or that affect the critical path of the schedule Cotnpany: Mitchell & Stark Construction Company, Inc. Signature: Date: 614120 Construction Solicitation Doc rev 02-21-20 0 Page 4268 of 7162 FORM 5 - STATEMENT OF EXPERIENCE OF BIDDER The Bidder is required to state below what work of similar magnitude completed within the last five ("5) years is a judge of its experience, skill and business standing and of its agility to conduct the work as completely and as rapidly as required under the terms of the Agreement. Babcock Ranch TCU project name) Charlotte Coons. F 1prida,, project location) WTP &_WWTP project description) 2t71h.7t)t7 . 1 4 00 ).O( project starCcompletion dates) (contract value) Babcock lunch Infrastruture project name) Charlotte „Counter Florida......._ . project location) Site Dc ek> mcnt _Uncier;rc unciUtiiitics____ project description) W } it gn,& Pr, -41L . . project owner} — ..._. __ _. 14750 SR 11, Punta Gnrdtt Flc7r da 33if12„ Owner' s address) John Broderick Vice „President Owner' s contact person) (title.) 441- 235-6907 com.._ phone) ( email) Kitson & Partners project owzter) 14750 S!2 31s.Punta C,«rdit 11t rrda.3398, Owner' s address) avid Mercer.,, .. P-.M.la. t Ma_ .,?a..ger. Owner' s contact person) (title) 2016; 20I8 _._......__.__ $,3i.000.U(3„ 239-567-5159 __. drticrca k >M)....t...... ;ratrx project stamcomplet ion dates) (contract value) (phone) (email) Pine Island,WWTP, lnYvrovements-,......__ .... project name) f' intw Island, Florida _ project location) e C;aunt_U iht rs...__ _.__ ..__.__. ,,, project owner) Port Myer, Owner' s address) titiAkP L'xpansion & Improvement,Mikes Maillakakis PE Proiect Mana v project description) ( Owner's contact person) (title) 1_, -21- 2 __. project starVcompletion dates) (contract value) 239-533- 8845.. a'unaillakakt si'Icc,1trti,.t7Jrrtt phone) (entail) Construction Solicitation Doc rev 02-21-20 c Page 4269 of 7162 FORM 5 - STATEMENT OF EXPERIENCE OF BIDDER 4, North Lee RO Expansion project name) North Fort Myers, FL project location) WTP Expansion project description) 10r2011 S 18,500,000 project completion date) (contract value) 5, NCWRF ASHT/r_Q3 Tank project name) Naples, FL. project location) WWTP EQ Expansion project description) 122014 S 5,902,000 project completion date) (contract value) 6. Gateway WWTP project name) Lee County. FL. project location) 2 MGD WWTP Expansion project description) t 112010 S 27,600,000 project completion date) (contract value) Lee County Utilities project owner) Fort Myers, FL Owner's address) Mikes Maillakakis Project Manager Owner's contact person) (title) — 239-533-8845 mmaillakakis(e leegov.com Phone),.,_._.—__ . (email)..,_._..____ _...__. C'ollierCounty BoC:'C project owner) 3299 Tamiami 'Nail East, Naples, Fl.. 34112 Owner's address) Pete Schalt Project 'Manager Owner's contact person) (title) 239- 252-5343 Peter.Schalt(q;cotliereountyil.gov phone) (email) Lee County Utilities project owner) Fort Myers, FI. Owner's address) Mikes Maillakakis Project Manager Owner's contact person) (title) 239- 533-8845 mmaillakakis(irrleegov.com phone) (email) Company: Mitchell & Stark Construction Company, Inc. PY _ ....._._......._.............._.._..._..___.............._....._._...__.__...__._._.._ ____....._.._.._. _. - 6t4/20 Signature: Construction Solicitation Doc rev 02-21-20 a Page 4270 of 7162 M Page 4271 of 7162 FORM 6 - TRENCH SAFETY ACT Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of lorida) effective October I, 1990, The Bidder further identifies the cost to be summarized below: French Safety Units of' Unit Unit Extended Cost Measure Measure (Quantity) cost Me-S.rjpfi.on) (IMF SY) IVV30 k (P<00 TOTAL $_ k Failure to complete the above may result in the Bid being declared non -responsive. Company Mitchell & Stark Construction Company, Inc. I.......... . ... . . ........... ..... Signature: . . . ... .... ..... Date. 6,14120 Construction Solicitation Doc rev 02-21-20 0 Page 4272 of 7162 EY3RlbI7-BIDBONDBUND_..... ._..... .... .... _., KNOW ALI. MEN BY THESE PRESENTS, that we MITCHELL&STARK CONSTRUCTION Ca., INC, (herein after called the Principal) and FIDELITY AND DEPOSIT COMPANY OF MARYLAND (herein called the Surety), a corporation chartered and existing under the laws of the State of MARYwND with its principal offices in the city of eALTIMORE and authorized to do business in the State of FLORIDA are held and firmly bound uftto the COLLIER COUNTY BOARD OF COMMISSIONERS (hereinafter called the Owner), in the full and just sum of FIVE 17046EN4'4'TimiE MAXIMUM 8 AMOLINT dollars ($ 5% I good and lawful money of the United States of America, to be paid upon demand of the Owner, to which payment well and truly to be made„ the Principal and the Surety bind themselves, their heirs, and executors, administrators, and assigns, jointly and severally and firmly by these presents. Whereas, the Principal is about to submit, or has submitted to the Owner, a Bid for furnishing all labor, materials, equipment and incidentals necessary to furnish, install, and fully complete the Work on the Project known as Bid No. 20- 7769.South County Regional Water Treatment Plant (SCRWTP) Reaetor Tank 44. NOW, TIDEKEFORE, if the Owner shall accept the Bid of the PRINCIPAL and the PRINCIPAL shall enter into die required Agreement with the Owner and within ten days after the date of a written Notice of Award in accoillance with the terms of such Bid, and give such bond or bonds in an amount of f 00% the total Contract Amount as specified in the Bidding Documents or Contract Documents with good and sufficient surety for the faithful pertorinance ofthe Agreement and for the prompt payment of labor, materials and supplies furnished in the prosecution thereof or, in the event of the failure of the PRINCIPAL. to enter into such Agreement or to give such bond or bonds, and deliver to Owner the required certificates of insurance, if the PR.INCPPAI.. shall pay to the OBI..IfiEE the fixed sum of S sx noted above as liquidated damages, and not as a penalty, as provided in the Bidding Documents, then this obligation shall be null and void. otherwise to remain in full force and effect. IN TD STIMONY Thereof, the Principal and Surety have caused these presents to he duly signed and sealed this 4TII__ . day of JUNE 2020 MIICHELL & 5TARK CONSTRUCTION CO., INC,Principal BY Seal) BRIAN PENNER. CEO j jar ,VS 'A 4L F10EL r?Y /4 j15 O `OSIT COMPANY of MARYt.AND Surety Seal) f2 Stir E s6r tAdvt3, JR ATTOPM' Y-SN FACT Countersigned Appointed Producing Agent for 00 Page 4273 of 7162 ZURICI I AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AN'D DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW,'V-L MEN DY'llff"Sl: PRESEN,rs:'Thai the ZURICII AMERICAN INSURANCE COMPANY, a corporation of the Suitt: of New York, the COLONIAL AMERICAN CASUALTY AND SLW,,.TY COMPANY, a corporation of the State of Illinois, and the FIDE11TY AND DEPOSITCOMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"). by ROBERT D. MURRAY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, arid appoint Robert F. WILLIAMS, JR., fill'Brownstown, Indiana, its true and lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as surety and as its act and deed: any and all bonds and undertakings, and the execution of sitch bonds or undertakings in pursuance of these presents, shall he as bindifig upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZUR ICB AMERICAN INSURANCE COXfPANY at its office in New York, New York., the regularly elected officers of the COLONIAL: AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Mnryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY 01' MARYLAND at its officc in Owings Mills. Maryhutd,, in their own Proper Persons. the said Vice President does hereby certity that th,, extract set forth on the reverse side hereof is a true copy of Article V, Section 8, oi' the By-1,aws of sail Companies, and is now in force. IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed hivbcr natnes and affixed the Corpoiate Seals of the stud ZURIC 11 AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, arid FIDEL) TV AND DEPOSIT COMPANY OF MARYLAND, (tits 2)1h day ot'July, A.D. 2019. ATTEST,. ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURE't V COMPANV F111. 41XI'VAM) IwPosry cOMPANY OF MARYLAND W P. N BY-, . ................. ............ ......................... . ......... ...... Assis- fant,Secrelaty Vice President Dawn E Brown Ron etf D. Murray State o(Mat, viand County of Baltimore On this 21Ah day of.fuly, A D. 2019, before the subscriber, a Notary Public of the Stale of Maryland, duly commissioned and qualified, ROBVRI I). NIVRRAY, Vice President, 2nd DAINN E, BROWN, Assistant Secretary, of the Companies, to me personally knowi to he the individuals and officers described in and who ex"uted the preceding instrument, and acknoMcdgcd the execution of same, and being by me duly sworn, dcpowth and saith, that he/ she i< the said officer of the Company aforesaid, and that the seals affixed to the, preceding instrument are the Corporate Seals of said ( i 'onipam", and 1141 the said Coriforatc, Seals and the signature as such offioa were duly affixed and stjbsczibcd to the said instrument by the authority and direction of the said Cut porai',014 INTESTIMONY WHERLOF, I have licitunto set my hand and affixed my Official Seat the day and year first aluive wrincti, My Cwrfrnisston Expires, July 9, 2C23 POA- F 044-3937A Page 4274 of 7162 FORM INSURANCE AND BONDING REQUIREMENTS The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in FORM 8 of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Vendor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf' of Collier County", or, the specific solicitation number and title. The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County. Florida. as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in FORM 8 with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Vendor has any self - insured retentions or deductibles tinder any of the below listed minimum required coverage, Vendor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be Vendor's sole responsibility. Covcrage,(sJ shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer, The Vendor and,or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non -renewal on the part of the insurance carrier or the Vendor. T'he Vendor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non - renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder. Vendor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverageUs required herein. the County Ina)' terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage Ds and charge the Vendor for such coverageLb) purchased, If Vendor fails to reimburse the County lor such costs within thirty (30) days after demand. the County has the right to offset these costs from any amount due Vendor under this Agreement or any other agreement between the County and Vendor. The Countyounty shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverageW purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverageW shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope orwork, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s) shall be considered justification fi)r the County to tenninate any and all contracts. 0 Page 4275 of 7162 Collier County Florida Insurance and Bonding Requirements Insurance / Bond Ifype Required Limits 1, Z Worker's Compensation Statutory I-imits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprictorships shall not be required to provide a proof of exemption. All application for exemption can be obtained online at IMps-.8a p,,fl, fs.comlbocexempt/ 2. Z Employer's Liability $1,000,000 single limit per occurrence 3, Z Commercial General Bodily Injury and Property Damage Liability (Occurrence Fonn) patterned after the $1,000,000 single limit per occurrence, $2,000, 000 aggregate for Bodily Injury current ISO form Liability and Property Damage I iability, This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4, Z Indemnification To the maximum extent permitted by Florida law, the Contractor Vendor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabiflifics, damages, losses and costs, including. but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor/ Vendor or anyune employed or utilized by the Contractor 'Vendor in the performance of this Agreement. 5. Z Automobile Liability 51,000,000 Each Occurrence, Bodily Injury & Property Damage. Owned'Non-owned4-fired; Automobile Included G. Z Other insurance as El Watercraft S,,,.............._.........._.._.Per Occurrence noted: El L.Jnited States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. S Per Occurrence Fj Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work, Per Occurrence Aircraft Liability coverage shall be carried in limits of not less than 55,000,000tr each occurrence if applicable to the completion of the Services under this Agreement. Per Occurrence Pollution $ 1,000,000 Per Occurrence E] Professional Liability Per claim & in the aggregate Project Professional Liability S .......... I ........... Per Occurrence Valuable Papers Insurance S Per Occurrence EJ Cyber Liability Per Occurrence M Technology Errors & Omissions Per Occurrence 0 Page 4276 of 7162 7. Z Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of eredit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. ® Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving; award, and written for 100%of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 9. ® Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. I'he same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. 10. JE Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. 'I his insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Vendor's policy shall be endorsed accordingly. I I . ® The Certificate Holder shall be named as Collier County Board of County Coin inissionets, OR. Board of County Commissioners in Collier County, OR Collier County Government. OR (:Iollier County. The Certificates of Insurance must state the Contract Number, or Project Number. or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12, Z On all certificates, the Certificate Bolder must read: Collier County Board of Commissioners. 3295 Tamiami Trail East, Naples, FL 34112 13, Z Thirty (30) Days Cancellation Notice required. 14. Collier ('ounty shall procure and maintain Builders Risk Insurance on all constriction projects where it is deemed necessary. Such coverage shall be endorsed to cover the interests of Collier County as well as the Contractor. Premiums shalt be billed to the project and the Contractor shall not include Builders Risk premiums in its project proposal or project billings. All questions regarding Builder's Risk Insurance will be addressed by the Collier County Risk Management Division. 4r27120 - CC Vendor's Insurance Acceptance By submission of the bid Vendor accepts and understands the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. The insurance submitted must provide coverage for a minimum of six (6) months front the date of award. 0 Page 4277 of 7162 Coiler Comiq Administrative Services Department Prrn:v e,mont senOr$15 ",*""'F,wn FORM 9 - CONFLICT OF (NURFsi, AFFIDAVIT I'tte Vendor certifies that, to the best of its knowledge and belief, the past and current work on any Collier County project affiliated with this solicitation does not pose an organizational conflict as described by one of the three categories below: Biased ground rules — The firm has not set the "ground rules" for affiliated past or current Collier County project identified above (e.g.. writing a procurement's statement of' work, specifications, or performing systems engineering and technical direction for the procurement) which appears to skew the competition in favor of my Finn. Impaired objectivity — The firm has not performed work on an affiliated past or current Collier County pro ject identified above to evaluate proposals % past performance of itself`or a competitor, which calls into question the contractor's ability to render impartial advice to the government. Unequal access to information —The firm has not had access to nonpublic information as part of its performance of a Collier County project identified above which may have provided the contractor (or an affiliate) with an unfair competitive advantage in current or future solicitations and contracts. In addition to this signed affidavit, the contractor I vendor must provide the following: I , All documents produced as a result of the work completed in the past or currently being worked on for the above - mentioned project; and, 2. Indicate if'the information produced was obtained as a matter of public record (in the "sunshine' or through non- public ('not in the "sunshine") conversation (s). mecting(s). document(s) and or other means. Failure to disclose all material or having an organizational conflict in one or more of the three categories above be identified, may result in the disqualification for future solicitations affiliated with the above referenced project(s). By the signature below. the firm (employees, officers and`or agents) certifies,. and hereby discloses, that, to the best of their knowledge and belief, all relevant facts concerning past. present, or currently planned interest or activity financial, contractual, organizational, or otherwise') which relates to the project identified above has been fully disclosed and does not pose an organizational conflict. Mitchell K Stark Construction Company, Inc, Cot7tpany Name Si matureMichaelP. Westhafer, Vice Presidenp 1. .............. _ . _ .........1.11111 Print name. and Title State of Florida Couruy of Lee The foregoing instrument was acknowledged before me by means of 0 physical presence or iJ online notarization, this 4th day of June (month), ^2020(year). by Michael P. e h (name of person acknow•led—ging); ' -__._...... / Jc,s Signature of ivotary Public - State of Florida) Print:, Type, or Stamp Commissioned Natne of Notary Public) Personally Known OR Produced identification W_..___.._._., E,, cifto!ary r tli 51ate ,r r `TypeofIdentificationProducedEarl [Ion ald Naa,typ Expires02,11112027 .i 0 Page 4278 of 7162 Copier C014tti11,y Administrallo Services Department r6i:lirpntF:-'^Y St;,`VIC:P,S C3?bi5 m FORM 10- VENDOR Dt;csLARA' trt*; STAUMENT BOARD OF COUNTY COMMISSIONERS Collier County Government Complex Naples, Florida 34112 Dear Commissioners: T'he Undersigned, as Vendor declares that this response is made without connection or arrangement with any other person and this proposal is in every respect fair and made in good faith. without collusion or fraud. The Vendor hereby declares the instructions, purchase order terms and conditions, requirements, and specifications/scope of work of this solicitation have been fully examined and accepted. The Vendor agrees. if this solicitation submittal is accepted, to execute a Collier County document for the purpose of establishing a formal contractual relationship between the firm and Collier County, for the performance of all requirements to which the solicitation pertains. The Vendor states that the submitted is based upon the documents listed by the above referenced Solicitation, Further, the vendor agrees that if awarded a contract for these goods and/or services, the vendor will not he eligible to compete., submit a proposal, be awarded, or perform as a sub - vendor for any future associated with work that is a result of this awarded contract. IN WITNESS WHEREOF. WE have hereunto sub ribgd our names on this 4th day of June 20..20in the County of .. LCe in the State of ort a Finn's Legal Mitchell & Stark Construction Company, Inc. Name: Address: 6001 Shirley Street City. State, Zip Naples. Fl. 34109 Code: Florida 845897 Certificate of Authority Document Number 35-0964820 Federal Tax Identification Number CCR ti or CAGE Code Only if Grant Funded 239-597-2165 Telephone: Email: mwesthafer(r%mitchellstark.coni Signature by: Typed and written) Michael P. Westhafer. Vice President Title: 0 Page 4279 of 7162 send payments to: required if(ifferent from above) Contact name: Title: Address: Chi State, All I'elephunc: Additional Cmitact Information Company name used as payee LniAL Office ser% icing (.'oilier County to place orders required if different Aum above! InWo name: I BE Address: its. State. All Telephone: F. MA I: Brian Penner Secolldar Contact for this Solicitation: E::nmil: bpennerivnlitchellsiark.con) Phone: 29.547-2IGs 0 Page 4280 of 7162 Co ier comnty Adnw%trative services Departmenl FORM II-IMN11CRATION AFF'IDAVITCERTIFICATION This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with formal solicitation submittals. Further, Vendors are required to be enrolled in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Vendor's bid. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company which will be produced at the time of the submission of the Vendor's bid or within five (5) day of the County's Notice of Recommend Award, FAILURE TO EXECUTE THIS AFFIDAVIT" CERTIFICATION AND SUBMIT WITH VENDOR'S PROPOSAIJBID MA1' DEEM THE VENDOR NON -RESPONSIVE, Collier County will not intentionally award County contracts to any Vendor who knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 U.S.C:°. Section 1324 a(c) Section 274A(e) of the Immigration and Nationality .Act ("IN.A"). Collier County may consider the employment by arry Vendor of unauthorized aliens a violation of Section 274A (e) of the iNA. Such Violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be grounds for unilateral termination of the contract by C,'olher County. Vendor attests that they are fully compliant with all applicable immigration laws (specifically to the 1986 Immigration Act and subsequent Amendment(s)) and agrees to comply with the provisions of the Memorandum of Understanding with F-Verify and to provide proof of enrollment in The Employment. Eligibility Verification System (E-Verii'N operated by the Department of Homeland Security in partnership with the Social Security .Administration at the time ol'submission of the Vendor's bid. Mitchell & Stark Construction Company. Inc. r---- pany Marne Signature Michael P. Westhafer, Vice President Print Name and Title State of Florida County of ..........,ce The foregoing instrument was acknowledged before me by means of d physical presence or 0 online notarization, this _4th day of June (month), 2020 (year), by l4Tichael P, Westhafer ramie of person acknowledging). ti._... _ .. Signature of Notary Public - State of Florida) Print, Type, or Stamp Commissioned Name of Notary Public) Personally Known OR Produced Identification Type of Identification Produced r: Earl Done jid rt ias p My COMM:W091 CG 184, 20 f k'Dire5 02//112022. 0 Page 4281 of 7162 FORM 12 - BIDDERS CHECKLIST 7771 IMPORJ'ANT: Please read carefully, sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: I , The Bid has been signed. — 2, The Bid prices offered have been reviewed. 3. The price extensions and totals have been checked. 4. Bid Schedule has been completed and attached. —` 5, Any required drawings, descriptive literature, etc, have been included, G. Any delivery information required is included. -` 7. The following on-line standard documents have been reviewed and accepted in BidSync: a. Construction bid instructions forrn b. Construction services agreement --' c. Purchase order terms and conditions 8. All of the following bid forms have been completed and signed: a. Bid Form (Form 1) -— b. Contractors Key Personnel (Form 2) c. Material Manuiacturers, (Form 3) -' d. List of Major Subcontractors (Form 4) e. Statement of Experience (Form 5) f. french Safety Act (Form 6) g. Bid Bond Form (Form 7) ' h, Insurance and Bonding Requirements (Form 8) i. Conflict of Interest Affidavit (Form 9) " j. Vendor Declaration Statement (Form 10) k. Immigration Law Affidavit Certification (Form I I) MUST he signed and attached with your submittal or you MAN' be DEEMED NON -RESPONSIVE 1, Signed Grants Provisions and Assurances Package in its entirely, if applicable, are executed and should be included with your submittal. All forms must be executed, or you MAI" be DEEMED NON -RESPONSIVE ---' 9, Copies of required information have been attached a. Business tax Receipt (Collier County Businesses Only) b, Company's E-Verify profile paCge or memorandum of understanding c. Certificate of Authority to Conduct Business in State of Florida (sunbiz.org) d. Any required professional licenses , valid and current (myfloridalicensc.com ic: General Contractors license, Underground Utility and Excavation, Builders, Trade Contractors, etc.. as applicable, requested and -'or required.) 10, If required, the amount of Bid bond has been checked, and the Bid bond or cashier's check has been submitted. 11, Any addenda have been signed and acknowledgement form attached and included, or you MAI' be DEEMED NON -RESPONSIVE. 12. The Bid will be uploaded in time to be received no later than the specified openirt1 date and time, otherwise the Bid cannot be considered. 0 Page 4282 of 7162 4 per. C tc3i' a. r Q z to cc z J w w a U) co m t% r o- zzq- ww im Lu U- hirj LL o CL cn E N zh u N uxxw 46 40UJ V J CD At u ((( JJJ ]] E n 1U CL W 15 LU U ;ice tj IR t- Jf LU > x; 'A $ 00 N Q rx Q o Ul) U) v $ a ew y O J N U lJJ uvruji Q 06 6 tti W u c i3Lcn< Page 4283 of 7162 E-, e Company ID Number: 99962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (Of IS) and the Mitchell & Stark Construction Co , Inc (Employer) The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E,Verify, F Verify is a pirogram that electronically confirms an employee's eligibility to work in the United Stater, after completion of Form 1-9, Employment Eligibility Verification (Form 1-9) This Memorandum of Understandinq ; MOIJ) explains certain features of the E -Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA) and DHS Authority for the F,Venty program is found in Title IV, Subtitle A. of the Illegal immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Put) L 104-208, 110 Stat 3009, as amended (8 J S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18 "Employment Eligibility Verification' and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal contractor) to use F-Verify to verify the employment eligibility of cetlain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system a Notice of E-Verily Participation b Notice of Right to Work 2 The Employer agrees to provide to the SSA and DHS the names, titles. addresses, arid telephone numbers of the Employer representatives lobe contacted about E -Verify The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information Change$ 3 The Employer agrees to grant E-Verify access only to current employees who need E -Verify access Employers rtiust promptly terminate an employee's F -Verify access it the employer is separated from the company or no longer needs access to E -Verify PA'Jt 101 0 Page 4284 of 7162 Company ID Number: _499r1 4 The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual, 5 The Employer agrees that any Employer Representative who will create E -Verify cases will complete the E -Verify Tutorial before that individual creates any cases a, The Employer agrees that at] Employer representatives will take the refresher tutorlaIS w tieM prompted by E-Verify in order to continue using E-Verity Failure to Complete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify 6 T he Employer agrees to comply with current Form 1-9 procedures. with two exceptions a It an employee presents a 'L ist 8' identity document the Employer agrees to only accept 'List E" documents that contain a photo. (List 8 documents identified in 8 C.F R § 274a 2(b)(1)(B)) car) be presented during the Form 1-9 process to establish identity,) It an employee objects to the photo requirement for religious reasons. the Employer should contact E-Verify at 888-464-4216 b II an employee presents a CHS Form 1-551 {Permanent Resident Card), Farm 1-766 rriployment Authorization Document). or U S Passport or Passport Card it) complete Form 1- 9 the Employer agrees to make a photocopy of IhP document and to retain the photocopy with the employee s Form 1.9 1 he Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest DHS may in the future deslqriate, other documents that activate (tie photo screening tool Note Subject only to the exceptions noted previously in this paragraph employees Mill retain the right to present any List A or List 8 and List C. document(s) to complete the Form 1-9 7 The Employer agrees to record The case verification number on the employee's Form 1-9 or to print the screen containing the, ease verification number and attach it to the employee's Form 1-9 8 The Employer agrees that. although it participates in E-Venfy, the Employer has a responsibility to complete, retain, and make available for inspection Fonts 1.9 that relate to its employees, or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 2746 of the INA with respect to Form 1-9 procedures a The following modified requirements are the only exceptions to an FmpIDyef s obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the IN& (1) List B identity documents must have photos, as described in paragraph 6 above: (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E -Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(a)(1)(A) of the immigration and Nationality Act (INA) with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmahon for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and ' 51,100 for each failure to notify DHS of continued employment following a final nonconfirmation; (4) If the Employer continues to employ an employee after receiving a final nonconfornalion, then the Employer is subject to a rebuttable presumption that it has knowingly PV,, ? M ` C Ve,Of MOu I'Ll, Hnplk,yfts, Reosioi Daft. 06,01,13 0 Page 4285 of 7162 E-Verify......z Company ID Number: 9W2 employed an unauthorized alien in violation of section 274A(a)(1)(A), and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verity b DHS reserves the right to conduct Form 1,9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verify 9 The Employer is strictly prohibited from creating an E -Verify case before the employee has been hired, meaning that a firm otter of employment was extended and accepted and Form 1.9 was completed The Employer agrees to create an E -Verify case for new employees within three Employer business days after each employee has been hired (after bolt) Sections 1 and 2 of For") 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the F-Verify User Manual If E-Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting in good faith, to make inquiries during the period of unavailability 10 The Employer agrees not louse E -Verify for preemployment screening of job applicants: in support of any unlawful employment practice, or for any other use that this MOU cir the E-Verity Use, Manual does not authorize 11 The Employer must use E-Venly for air new employees 1 fie Employer will not verity selectively and will not verify employees hired before the effective date of this MOU Employers who are Federal contractors may quality for exceptions to this requirement as described in Article li,B of this MOU 12 The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employees F -Verity case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding and not take adverse action against employees if they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmalion based upon a photo mismatch, the Employer must take additional steps see Article III B below) to contact MiS with infoirmalion necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or OHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C F,R § 274a, 1(l)) that the ernployele, is not work authorized The Employer understands that an initial inability of the SSA or OHS automated verification system to verity work authorization, a tentative nonconfirmation, a case in continuance indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized In any of such cases, the employee must he provided a full and fair opportunity to contest the finding: and of he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status FaV 3 DI 17 F,vtnf f.AD,,# to, frnployt,s ! Pey,vo+ Wie 0 Page 4286 of 7162 Company ID Number; 9M2 including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or OHS has been completed and a final nonconfirmation has been issued. If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers of employees with questions about a final nonconfirmation may call E-Verify at 1-888A64- 4218 (customer service) or 1.88&-897-7781 (worker hotline) 14 The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 274B of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by commintrig discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E-Verify except as provided in part D Wow, or discharging or refusing to hire employees because they appear or sound foreign- or have received tentative nonconfirmattons The Employer further understands that any violation of the, immigration -related unfair employment practices provisions in section 274E of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title Vil could subject the Employer to back pay awards, compensatory and punitive damages Violations of either section 2746 of the INA or Title V11 may also lead to the termination of its participation in F-Verify If the Employer has any questions relating to the anti -discrimination provision it should contact OSC at 1.800-255-8155 or 1-800.237-2515 JDD) 15 The Employer agrees that it will use the information it receives front E-Verify only to confirm the employment eligibility of employees as authorized by this MIOU The Employer agrees that 1 will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality. including ensuring that it is not disseminated to any person other than employees of the Employer who are authori2ed to perform the Employer's responsibilities under this MOU except for such dissemination As may be authorized in advance by SSA or OHS for legitimate purposes 16 The Employer agrees to notify OHS immedratefyin the event of a breach of personal information Breaches are defined as loss of control or unauthorized access to E-Verify personal data All su"cled or confirmed breaches should be reported by calling 1-888-464.4218 or via email at E-VerifyPdhs.qoy Please use "Privacy Incident - Password' in the subject line of your email when sending a breach report to E-Vertty 17 The Employer acknowledges that the information it receives from SSA is governed by I fie Privacy Act J5 U,S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)) Any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties 18 The Employer agrees to cooperate with OHS and SSA in their compliance monitoring and evaluation of F-Verify, which includes permitting OHS SSA. their contractors and other agent, upon Page 4 CY 9 F Vt"'N MOU to, Revis,on Ua!t W01113 ICAOCAO Page 4287 of 7162 Campany to Numbev 9VA2 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-VOfy, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Venty. 19 The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media The Employer shall not describe its services as federally -approved, federally -certified, or federally -recognized, or use language with a similar intent on its website of other materials provided to the public Entering into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effect is false 20 The Employer shall not state in its website of other public documents that any language used therein has been provided or approved by OHS. USCIS or the Verification Division, without first obtaining the prior written consent of DHS 21 The Employer agrees that E-Verify trademarks and logos maybe used only under license by DHS/USCIS (see M-72§ Web terms of such license, may notL ... J) and, other than pursuant to the specific be used in any manner that might imply that the Employer's services products, websites, or publications are sponsored byendorsed by, licensed by, or affiliated with DHS, USCIS. or E -Verify 22 The Employer understands that it it uses E Verify procedures for any purpose other tnan, as authorized by this MOU. the Employer may be subject to appropriate legal action and termination of its participation in E-Verify, according to this MOU B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1 It the Employer is a Federal contractor with the FAR E-Venty clause subject to the empi0yrneill verification terms in Subpart 22 18 of the FAR, A wili become farnifiaf with and comply with the most current version of the E-Venfy User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands, that if it is a Federal contractor subject to the employment verification leans in Subpart 22.18 of the FAR it must verity the employment eligibility of any 'employee assigned to the contract" (as defined in FAR 22 1801) Once an employee has been verified through E-Verily by the Employer the Employer may not create a second case for the employee through E-Verity. a An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verity employment eligibility of new hires usingE- Verify The Employer must verity those employees who are working in the United States, whether or not they are assigned to the contract Once the Employer begins verifying new hires such verification of new hires must be initiated within three business days after the hire date Once enrolled in E-Verify as a Federal contractor, the Employer must begin verification Of tfnpI0yeeS assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee' s assignment to the contract, whichever date is later Paqu t 0 , ? E VeOMOU to, Ery'krus I Care OCOIQ Page 4288 of 7162 Company 10 Number : 9-0%2 b. Employers enrolled in E-Verify as a Federal contractor tot 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility tot new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Employer must, within 90 days of enrollment, begin to use E-Verity to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract Such verification of new hires must be initiated within three, business days after the date of hire An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later c Federal contractors that are institutions of higher education (as defined at 20 U S C stale of local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986 Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employees assignment to the contract, whichever date is later d Upon enrollment. Employers who are Federal contractors may elect to verity employment eligibility of all existing employees working in the United States who were hired after November 6., 1986, instead of verifying only those employees assigned to A covered Federal contract Aftef enrollment, Employers must elect to verify existing staff following DNS procedures and begin E Verify verification of all existing employees within 180 days after the election e The Employer may use a previously completed Form 1.9 as the basis tot creating an L Verify case for an employee assigned to a contract as long as That Form 1-9 is complete (including the SSN) and complies with Article 11 A is it The employee's work authorization has not expired and iii. The Employer has reviewed the Form 1.9 informat-on either in person of in communications with the employee to ensure that the employee's Section 1, F orrn 1-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U.S. citizen) f The Employer shall complete a new Form 1.9 consistent wish Article 11 A 6 or krpdate the previous Form 1.9 to provide the necessary information if I The Employer cannot determine that Form 1-9 complies with Article If A.6. it The employee's basis tot work authorization as attested in Section 1 has expired of changed, or fit The Form 1-9 contains no SSN of is otherwise incomplete Note If Section 1 of Form 1.9 is otherwise valid and up-to-date and the form otherwise complies with Pj9t- tot I 7 f vtflfy PAW to, 1^01oyufE . Rev,sion Wit, 06,01;13 0 Page 4289 of 7162 Company ID Nurriber; 99%2 Article 11 C.5, but reflects documentation (such as a U,S. passport or Form 1-551) that expired after completing Form 14 the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article IIA5 subject to any additional or superseding instructions that may be provided on this subIecl in the E-Verily User Manual 9 The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU of to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that if it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract of subcontract, and the Employer consents to the release of information (elating to compliance with its verification responsibilities under this MOU to contracting officers of other officials authorized to review the Employer's compliance with Federal contracting requirements, C. RESPONSIBILITIES OF SSA I SSA agrees to allow DHS to compare data provided by the Employer against SSAs database SSA sends DHS confirmation that the data sent either matches of does not match the information in SSA s database 2 SSA agrees 10 safeguard the information the Employe( provides through E, Verity procedures SSA also agrees to limit access to such information. as is appropriate by law, to indIV4dual,, responsible for the verification of Social Security numbers of responsible for evaluation. of E -Verity or such other persons or entities who may be authorized by SSA as governed by the Privacy Act (5 U 5 C § 552a) the Social Security Act (42 LJI S.0 1306(a)), and SSA reclulations (20 CFR Parl 401) 3 SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry E-Verify provides the information to the Employer. 4 SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence If the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, it appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary In such cases. SSA will provide additional instructions to the employee If the employee does not visit SSA in the time allowed, E -Verify may provide a final nonconfirmation to the employer Note If an Employer experiences technical problems, of has a policy question, the employer should contact E.-Verify at 1-888-464-4216 O. RESPONSIBILITIES OF OHS 1 OHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct. to the extent authorized by this MOU a Automated verification checks on alien employees by electronic means, and Pwr, " o! I? I vtnfy Mou for trrptyer, I Revrsg)n Oalt 06:0113 0 Page 4290 of 7162 Company ID Number: 99962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DHS) and the Mitchell & Stark Construction Co , Inc (Employer) The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in F-Verify. F-Verify is a program that electronically confirms an employee's e69,bfI!Iy to work in the United States after completion of Form 1.9, Employment Eligibility Verification (Form 1-9) This Memorandum of Understanding (MOO) explains certain features of the E-Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA), and DHS Authority for tne I -Verity program is found in I site IV, Subtitle A. of the Illegal immigration Reform and Immigrant Responsibility Act at 1996 (IIRIRA), Put) L 104-208, 110 Stat 3009 as amended (6 U S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18 "Employment Efigiblilly Verification' and Executive Order 12989, as amended provide authority for Federa! contractors and subcontractors (Federal contractor) to use E-Verify to verify the employment eligibility of certain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER I The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system a Notice of E-Verify Participation b Notice of Right to Work 2 The Employer agrees to provide to the SSA and DHS the names, lilies, addresses. and telephone numbers of the Employer representatives to be contacted about E -Verify The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes 3. The Employer agrees to grant E-Verify access only to current employees who need E-Versify access Employers must promptly terminate an employee's E -Venty access if the employer is separated from the company or no longer needs access to E -Verify F'49# 10 17 [-Verity Wu to, Empkqt-f, I Re.,s*a [)ale 06?C v I 0 Page 4291 of 7162 1111.— V er"Ify— Company ID Numbvv 99962 4 The Employer agrees to become familiar with and comply with the most recent version of the E- Verify User Manual. 5. The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E -Verify Tutorial before that individual creates any Cases a The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E -Verity in order to continue using E -Verify Failure tocomplete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify 6 1 he Employer agrees to comply with current Form 1,9 procedures, with two exceptions a It an employee presents a *List 8' identity document, the Employer agrees to only accept "List S' documents that contain a photo. (List 8 documents identified in 8 C F R § 274a 2ftl)(B)) can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons, the Employer should contact E-Verify at 898- 464-421& b If an employee presents a DNS Form 1-551 (Permanent Ret.,ideni Card), Form 1-766 Employment Authorization Document), or U S Passport or Passport Card to complete Farm 1.9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employees Form 1-9, The Employes will use the photocopy to verify the photo and to assist OHS with its review of photo mismatches that employees contest DfiS may in the future designate other documents that activate the photo screening tool Note Subject only to the exceptions noted previously in this paragraph, employees still retain the rf(Jhl to present any List A or List 8 and List C. document(s) to complete the Form 1.9 7 The Employer agrees to record the case verification number on the employee's Form 1.9 or to print the screen containing the case verification number and attach it to the employee's Form 1-9 8 The Employer agrees that, although it participates in E-Verify, the Employer has a responsibility to Complete, retain, and make available for inspection Forms 1-9 that relate to its employees. or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 274E of the INA with respect 10 Form 1,9 procedures. a The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the antidiscrimination provision of the INA, (1) List 8 identify documents must have photos, as described in paragraph 6 above: (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the E mptoyer establishes a rebuttable presumption that it has not violated section 274A(ay 1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of that employee; 3) If the Employer receives a final nonconfirmation for an employee. but continues to employ that person, tie Employer must notify DNS and the Employer is subject to a civil money penalty between $550 and $ 1, 100 for each failure to notify OHS of continued employment following a final nonconfirmation, ( 4) If the Employer continues is employ an employee after receiving a final ncnconfirmabon, then the Employer is subject to a rebuttable presumption that it ha, knowingly f, agt ; of 17 F VtqifV JK)J fog Fjr.r.;0,*,S Rii,l%ion [)ate 06,,01,111 0 Page 4292 of 7162 E-Varify---- Company 10 Number , 99962 employed an unauthorized alien in violation of section 274Na)(1)(A), and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verity, b DNS reserves the right to conduct Form 1-9 compliance inspections as well as any other enforcement or compliance activity authorized by taw, including site visas, to ensure proper use of E-Verify, 9 The Employer is strictly prohibited from creating an E-Verity case before the employee has been hired, meaning that a form offer of employment was extended and accepted and Form 1-9 was completed The Employer agrees to create anE-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections I and 2 of Form 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the F-Verity User Manual If E -Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate, the Employer's attempting, in Good faith, to make inquiries during the period of unavailability 10 The Employer agrees not to use E-Verify for pre -employment screening of job applicants, in support of any unlawful employment practice or for any other use that this MOU or the E-Verify Use, Manual does not authorize 11 The Employer must use E -Verify for all new employees The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article ILB of thi,_s, MOU 12 The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations The Employer must promptly notify employees in prtvate of the finding and provide them with the notice and letter containing information specific to the employees E -Verify case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding, and not lake adverse action against employees if they choose to contest the finding• while their case is still pending Further, when employees contest a tentative nonconfirmalion based upon a photo mismatch, the Employer must take additional steps see Article III B below) to contact DNS with information necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DNS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C F R § 274a 1(l)) that the employee is not work authorized The Employer understands that an initial inability of the SSA or DHS automated verification system to verify work authorization, a tentative nonconfirmation, a case in continuance indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized In any of such cases, the employee must be provided a lull and fair opportunity to contest the finding. and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status PaOf icy! 17 F,V*14 MO•O to, Imotovert " Rews,on Wit WUII13 0 Page 4293 of 7162 CornPany IU Nunibei 49%2 including denying, reducing, or extending work hours, delaying of preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218 (customer service) or 1.888-897-7781 (worker hotline) 14 The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 2748 of the INA as applicable by not discriminating unlawfully against any Individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E-Venty except as provided in part D below, or discharging or refusing to hire employees because they appeal of sound foreign" or have received tentative nonconfirmalions The Employer further understands that any violation of the immigration -related unfair employment Practices Provisions In section 2748 of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject the Employer to back pay awards compensatory and punitive damages Violations of either section 2748 of the INA or Title VII may also lead to the termination of its Participation in E-Venfy If the Employer has any questions relating to the anti -discrimination provision, it should contact OSC at 1-800.255-8155 or 1.800-237-2515 (TDD) 15 The Fmployer agrees that it will use tree information it receives from E-Verify only to confirm the, employment eligibility of employees as authorized by this MOU The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who rare authorized to perform the Employer's responsibilities under this MOU, except for such dissemination as may be authorized in advance by SSA of DHS for legitimate purposes 16 The Employer agrees to notify DHS immediately in the event of a breach of personal information breaches are defined as loss of control or unauthorized access to EVerity personal data. All suspected or confirmed breaches should be reported by calling 1-888,464-4218 or via email at E- Yerify0dh§,..qq yPlease use Privacy incident - Password' in the subject line of your email when sending a breach report to E -Verity 17 The Employer acknowledges that the Information it receives from SSA is governed by the Privacy Act ( 5 U.S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)). Any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOO may be subject to criminal penalties 18 The Employer agrees to cooperate with OHS and SSA in their compliance monitoring and evaluation of E-Verify. which includes permitting OHS SSA, their contractors and other agents, upon Wage A 01 11 (-vwls Mfor CMP1*YVS i ke.t5mn Gait W01103 0 Page 4294 of 7162 Compony ID Nvmbef99%2 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19 The Employer shall not make any false or unauthorized claims or references about its participation in E-Venty on Its website, in advertising materials, or other media The Employer shall not describe 4s service.- as federally -approved, federally -certified, or federally- recognized, or use language with a similar intent on its website or other materials provided to the public Entering into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effecl is false 20 The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS 21 The Employer agrees that E-Verify trademarks and logos may be used only tinder license by DHS/ USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services, products, websites, of p, iblications are sponsored by, endorsed by, licensed by: or affiliated with DHS, USCIS or E--Verify 22 The Employer understands that it it uses E Verify procedures lot any purpose other than as authorized by this MOU. the Employer may be subject to appropriate legal action and termination of Its participation in E -Venty according to this MOU B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1 If the Employer is a Federal contractor with the FAR F-Venty clause subject to the employment verification terms in Subpart 22 18 of the FAR, I wilbecome familiar with and comply with the most current version of the F.-Venty User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must verity the employment eligibility of any 'employee assigned to the contract' (as defined in FAR 22 1801) Once an employee has been verified through E.-Verify by the Employer. the Employer may not create a second case for the employee through E-Verify a An Employer that is not enrolled in E-Verity as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verify employment eligibility of new hires using E- Verify The Employer must verify those employees who are working in the United States, whelhe( or not they are assigned to the contract Once the Employer begins verifying new hires, such verification of new hires must be initiated within three business days slier the hire date Once enrolled in E -Verify as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment of within 30 days of an employee's assignment to the contract, whichever date is later Page b 01 1: v(-.0) MOU IV Efr.plcyers I Hey'von Wit! 06,01,13 0 Page 4295 of 7162 Am=* M M tiveri f Company 10 Numbec 9W2 b Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Emptoyet must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract Such verification of new hires must be initiated within three business days after the dale of hire An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the cuntract, whichever is later. c Federal contractors that are institutions of higher education (as defined at 20 U S C. 1001 (a)), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however elect to verify all new hires. and/or all existing employees hired after November 6, 198433 Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee s assignment to the contract, whichever date is later d Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United States who were hired after November 6, 1966, instead of verifying only those employees assigned to a covered Federal contract After enrollment, Employers must elect to verify existing staff following DNS procedures and begin C -Verify verification of all existing employees within 180 days after the election. c The Employer may use a previously completed Form 1-9 as the basis tot cresting an, E-Verify case tot an employee assigned to a contract as long as. That Form 1-9 is complete (including the SSN) and complies, with Article ILA 6 ii The employees work authorization has not expired and iii. The Employer has reviewed the Form 1-9 information either in per sari or in communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U S citizen) I The Employer shall complete a new Form 1-9 consistent with Article 11 A 6, or update the previous Form 1.9 to provide the necessary information it 1 The Employer cannot determine that Form 1-9 complies with Article HA 6. ii The employee's basis for work authorization as attested in Section 1 has expired or changed.or in The Form 1.9 contains no SSN or is otherwise incomplete Note If Section I of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies w1th Paget 0 1;( Vtnfy PAO-1 V F. nDioytr.- Re vimvi Wit, 0-5101;13 0 Page 4296 of 7162 Company ID Number, 90-%-2 Article It C.5, but reflects documentation (such as a U.S passport or Form 1-551) that expired after completing Form 1.9, the Employer shah not require the production of additional documentation, or use the photo screening tool described in Article II.A.5. subject to any additional or superseding instructions that may be provided on this subject in the E•Verify User Manual g The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that it it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontractand the Employer consents to the felease of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements C, RESPONSIBILITIES Of SSA I BSA agrees to allow OHS to compare data provided by the Employer against BSA's database SSA sends OHS confirmation that the data sent either matches of does not match the information in SSA's database, 2 SSA agrees to safeguard the information the Employer provides through E Verity Procedures SSA also agrees to iimd access to such information, as is appropriate by law, to individuals responsible for the verif tcation of Social Security numbers of responsible for evaluation of E -Verify or such other persons or entities Who may be authorized by BSA as govemed by the Privacy Act (5 U S C § 552a), the Social Security Act (42 U S C 13%(a)), and BSA regulations (20 CFR Part 401) 3 BSA agrees to provide case results from its database within three Federal Government workdays of the initial inquiry E -Verify provides the information to the Employer 4 BSA agrees to update BSA records as necessary if the employee who contests the BSA tentative nonconfirmation visits an BSA field office and provides the required evidence If the employee visits an BSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, if appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary In such cases BSA will provide additional instructions to the employee If the employee does not visit BSA in the time allowed, E Nerify may provide a final nonconfirmation to the employer. Note: If an Employer experiences technical problems, of has a policy question, the employer shouid contact E-Verify at 1.888-464-4218 D. RESPONSIBILITIES OF OHS I DNS agrees to provide the Employer with selected data from DNS databases to enable the Employer to conduct, to the extent authorized by this MOU a Automated verification checks on alien employees by electronic rneans, and page 7 04 1) k veor kfou (t)t tmpfoyefs I RfV,W.rn Date 06,1,Wl3 00 Page 4297 of 7162 E Ve r i fy__ company ID Number: 99962 b. Photo verification checks (when available) on employees 2 DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. OHS agrees to provide the Employer names, titles, addresses, and telephone numbers of OHS representatives to be contacted during the E-Venty process 3 OHS agrees to provide to the Employer with access to E-Verify training materials as well as an E-Verify User Manuel that contain instructions on E-Verify policies procedures, and requirements for both SSA and OHS, including restrictions on the use of E-Verily 4 DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manuel Even without changes 10 E-Verify OHS reserves the right to require employers to take mandatory refresher tutorials 5 DHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E -Venfy. OHS also agrees to provide to the Employer anti -discrimination notices issued by the Office of Special Counsel for immigration -Related Unfair Employment Practices (OSC), Civil Rights Division. U S Deparimerill of Justice 6 DHS agrees to issue each of the Employer s E-Verify users a unique user identification number and password that permits them to tog in to E Verify 7 DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E-Verify, or to such other persns or entities as may be authorized by applicable law Information will be used only to verify the accuracy of Social Security numbers and employment eligibility, to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements. 8 DHS agrees to provide a means of automated verification that provides (in conjunction w4h SSA verification procedures) confirmation or tentative nonconfirmalion of employees' employment eligibility within three Federal Government work days of the initial inquiry 9, DHS agrees to provide a means of secondary verification (including updating OHS records) for employees who contest OHS tentative nonconfirmations, and photo mismatch tentative nonconfirmations This provides final confirmation or nonconfirmation of the employees* employment eligibility within 10 Federal Government work days of the date of referral to DHS. unless DHS determines that more than 10 days may be necessary In such cases. DHS will provide additional verification instructions ARTICLE III REFERRAL_ OF INDIVIEWALS TO SSA AND OHS A. REFERRAL TO SSA 1 If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the ernployee's E-Verify Page 0 D1 17 t VefVy MOU to, Fmt)i0iW, Is.. Rev -go, 09it D61(31,13 Page 4298 of 7162 Company ID Number: 99962 b Photo verification checks (when available) on employees, 2 OHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verity OHS agrees to provide the Employer names, titles, addresses, and telephone numbers of OHS representatives to be contacted during the E-Verify process 3. OHS agrees to provide to the Employer with access to E-Verify training materials as well as an E -Verify User Manual that contain instructions on E-Verify policies, procedures, and requirements for both SSA and DHS, including restrictions on the use of E-Verify. 4 OHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manual Even without changes to E .,Verify, OHS reserves the right to require employers to take mandatory refresher tutorials 5 OHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E -Venfy DHS also agrees to provide to the Employer anti -discrimination notices issued by the Office of Special Counsel for Immigration -Related Unfair Employment Practices (OSC), Civil Rights Division, 0 S. Department of Justice 6 DHS agrees to issue each of the Employer's E -Verify users a unique user identification number art,) password that permits them to log in to E-Verify 7 DHS agrees to safeguard the information the Employer provides, and to Ilmd access to such information to individuals responsible for the verification process for evaluation of E-Verify, or to such other persons or entities as may be authorized by applicable law Information will be used only to verity the accuracy of Social Security numbers and employment eligibility. to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements 8 OHS agrees to provide a means of automated verification that provides (in conjunction with SSA verdicalion procedures) confirmation or tentative nonconfirmalion of employees' employment eligibility within three Federal Government work days of the initial inquiry 9 OHS agrees to provide a means of secondary verification (including updating OHS records) for employees who contest OHS tentative nonconfirmations and photo mismatch tentative nonconfirmations This provides final confirmation of nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS, unless DHS determines that more than 10 days may be necessary In such Gases, DHS will provide additional verification instructions ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA I If the Employer receives a tentative nrinconfinnation issued by SSA. the Employer must print the rot" as directed by E -Verify The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the ernployee's E-Verify Page 9 01 17 E Venly MOU fe± Ffn0foyers I pe.jsolt Date. W0103 0 Page 4299 of 7162 A1,111:1,"I'll611rif Y Company to Number 99962 case The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation Only the employee may determine whether he or she will contest the tentative nonconfirmation 3 After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed by E-Verify The Employer must record the case verification number, review the employee information submitted to E-Verify to identify any errors, and find out whether the employee contests thc, tentative nonconfirmation The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again it this review indicates a need to do so 4 1 he Employer will instruct the employee to visit an SSA office within eight F elde rat Government wort; days SSA will electronically transmit the result of the referia± to the Employer within 10 Fecleta( Government worm days of the referral unless it determines that more than 10 days is necessary 5 While waiting for case results the Employer agrees to Check the E -Verify system regularly for case updates 6 The Employer agrees not to ask the employee to obtain a printout from the Social Security Administration number database (the Numident) or other written verificalion of the SSN from the SSA B. REFERRAL TO DHS I If the Employer receives a tentative nonconfirmation issued by OHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E -Verify case The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the, tentative nonconfirmation Only the employee may determine whether he or she will contest the tentative nonconfirmation 3 The Employer agrees to refer individuals to OHS only when the employee chooses to contest a tentative nonconfirmation 4 If the employee contests a tentative nonconfirmation issued by OHS, the Employer will instruct the P40f 401 11 F Vtnfy MOU 6 Emrloyr" I R,-4,von Oar* 06ro 1, 13 a Page 4300 of 7162 erify__zIr Company 10 Numbec 99962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DfIS) and the Mitchell & Stark Construction Co, Inc (Employer) The purpose of This agreement is to set forth terms and conditions which the Employer will follow while participating in F-Verify F Verify is a program that electronically confirms an employee's eligibility to work in the United States after completion of Form 1-9, Employment Eligibility Verification (Form 1-9) This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA), and DNS Authority for the IF -Verity program is found in Title IV, Subtitle A. of the Illegal Immigration Reform and Immigrant Responsibility A0 of 1996 (IIRIRA). Pub L 104.208, 110 Stat 3009. as amended (8 U S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18 'Employment Eligibility Verification" and Executive Order 12989. as amended provide authority for Federal conlraclors and subcontractors (Federal contractor) to use E-Verily to verify the employment eligibility of certain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER 1 The Employer agrees to display the following notices supplied Uy DNS in a prominent place that is clearly visible to prospective employees and all employees who are Ic be verified through the system a Notice of E-Verily Participation b Notice of Right to Work 2 The Employer agrees to provide to the SSA and DNS the names, titles. addresses, and telephone numbers of the Employer representatives to be contacted about E -Verity The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes 3 The E mptDyer agrees to grant E -Verify access only to current employees who need E-Verify access Employers must promptly terminate an employee',, E-Venfy access if the employer is separated from the company or no longer needs access to E -Verify Flav , 0 17 1, "Ve"i" "Ou roc Umpiovos I Rev;soon 08tr WO 1; 1A, a Page 4301 of 7162 mom i-Verif y...... Company ID Number. 99%2 4 The Employer agrees to become familiar with and comply wilh the most recent version of the E-Verify User Manuel. 5 The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases a The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E-Verify in order to continue using E-Verify. Failure to complete a refresher lulonal will prevent the Employer Representative from continued use of E-Verity 6 The Employer agrees to comply with current Form 1.9 procedures, with two exceptions a 11 an employee presents a 'List 6* identity document, the Employer agrees to only accept "List E' documents that contain a photo, (List 6 documents identified in 6 C,F R § 274a 2( b)(1)(8)) can be presented during the Form 1-9 process to establish identity.) If an employee objects In the photo requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218 b If an employee presents a DHS Form 1.551 (Permanent Resident Card). Form 1-766 Employment Authorization Document), or U S Passport or Passport Card to complete Form 1-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employees Form 1-9, The Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest DHS may in the future designate other documents that activate the photo screening tool Note Subject only to the exceptions noted previously in this paragraph, employees still retain the right to present any List A, or List 8 and List C. document(s) to complete the Form 1-9 7 The Employer agrees to record the case verification number on the employee's Form 1-9or to print the screen containing the case verification number and attach 0 to the employee's Form 1,9 8 The Employer agrees that, although it participates in E-Verify, the Employer ties a responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from other requirements of applicable regulations or laws, including The obligation to comply with the antidiscrimination requirements of section 2746 of the INA with respect to Form 1-9 procedures a The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the INA. (1) List 6 identity documents must have photos, as described in paragraph 6 above-, (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(ay, 1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of that employee-, (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penally between $550 and S 1,100 for each failure to notify DHS of continued employment following a final nonconfirmation: (4) It the Employer continues to employ an employee after receiving a final nonconfirmalion, then the Employer is subject to a rebuttable presumption that it has knowingly i"o9t r of I r I voif) MOa knF f-rrp"ers ke-wo- Date 06 01, 1) 0 Page 4302 of 7162 Company 10 Numbev 49%2 employed an unauthorized alien in violation of section 270(a)(1)(A), and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b OHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visilS, to ensure proper use of E-Verity. 9 The Employer is strictly prohibited from creating an E-Veyify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed The Employer agrees to aeate an E -Verity case for new employees within three Employer business days after each employee has been hired {after both Sections I and 2 of Form 1-9 have beer) completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual It F-Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting, in good faith. to make inquiries during the period of unavailability 10 The Employer agrees not to use E-Verity for pre -employment screening of job applicants, in support of any unlawful employment practice, or for any other use that this MOV of the E -Verify Use, Manual does not authorize 11 The Employer must use E-Venly for all new employees The Employer will not verity selectively and will not verily employees hired before the effective dale of this MOU Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article 11.8 of thiw MOU 12, The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSAThe Employer must allow employees to contest the finding, and not lake adverse action against employees erintosif they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmation based upon a photo mismatch, the Employer must lake additional steps see Article III B below) to contact OHS with information necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee' s perceived employment eligibility status while SSA or OHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a, 1(l)) that the employee, is not work authorized The Employer understands that an initial inability of the SSA or OHS automated verification system to verity work authorization, a tentative nonconfirmation. a case in continuance indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is riot work authorized In any of such cases, the employee must be provided a full and fair opportunity to contest the finding and it he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status Papf 3 (if 17 F-vWifi P,10,J lo, PMployets I Rev"'On Date (It"Wila 0 Page 4303 of 7162 17 Ve r"Ify a Tr -, Company ID Nutirtber. 99962 including denying, reducing, or extending work hours, delaying of preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or OHS has been completed and a final nonconfirmation has been issued It the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218 (customer service) or 1-888- 897-7781 (worker hotline) 14 The Employer agrees to comply with Title Vil of the Civil Rights Act of 1964 and section 2748 of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or tier national origin or citizenship status, of by committing discriminatory documentary practices The Employer understands that such illegal practices can include selective verification or use of E-Verity except as provided in part D below, or discharging or refusing to hire employees because they appear or sound foreign' or have received tentative nonconfirimations 'The Employer further understands that any violation of the immigration related unfair employment practices provisions in section 274E of the INA could subject the Employer to civil penalties, back pay a -wards, and other sanctions, and violations of Title Vil could subject the Employer to back pay awards, compensatory and punitive damages Violations of either section 2.74B of the INA or Title V1 I may also lead to the termination of its participation in E-Venfy, If the Employer has any questions (elating to the arilt-dissemination provision, it should contact CISC at 1.800-255-8155 or 1-800.237-2515 (TDD) 15 The Employer agrees that it will use the information it receives from E-Verity only to confirm the employment eligibility of employees as authorized by this MOtl The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to project its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU. except for such dissemination as may be authorized in advance by SSA or OHS for legitimate purposes 16 The Employe( agrees to notify DHS immediately in the event of a breach of personal informaltur) Breaches are defined as loss of control or unauthorized access to E Verify personal data All suspected or confirmed breaches should be reported by calling 1,888-464-4218 or via email at E-Vefify0dh _q_qy Please use "Privacy Incident - Password' in the subject line of your email Mien sending a breach report to E -Verity 17 The Employer acknowledges that the information it receives from SSA is governed by the Privacy Act (5 U.S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)) Any person who obtains this information under false pretenses of uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties 18 Ihe Employer agrees to cooperate with OHS and SSA in their compliance monitoring and evaluation of E-Verity, which includes permitting DHS SSA, their contractors and other agents, upon Page 4 01 0 F ver'N Mold fol EmAlogers . pews;m Cate 06,01113 0 Page 4304 of 7162 Company 10 Numbef. 99%2 reasonable notice, to review Forms 1.9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19 The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on Its website, in advertising materials, or other media The Employer shall not describe its services as federally -approved, federally -certified, or federally- recognized, or use language with a similar intent on its websile or other materials provided to the public Entering Into this MOU does not mean that F-Venty endorses or authorizes your E-Venly, services and any claim to that effect is false. 20 The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS 21 The Employer agrees that E-Verify trademariks, and logos may be used only tinder license by DHS/USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may nr.,l be used in any manner that might imply that the Employer's services products, websiles, of publications are sponsored by, endorsed by, licensed by, or affiliated with DHS. USCIS or L,Vefify 22 The Employer understands that if it uses E Verify procedures for any purpose other than as authorized by this MOU, the Employer may be subject to appropriate legal action and termination of its participation in E,Verify according to this MOU 6, RESPONSIBILITIES OF FEDERAL CONTRACTORS I It the Employer is a Federal contractor with the FARE -Venty clause subject 10 the employment verification terms in Subpart 22 18 of the FAR, it will become familiar with and comply with the most current version of the E. Verity User Manual for Federal Contractors as well as the E-Verity Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must venly the employment eligibility of any 'employee assigned to the contract' (as defined in FAR 22 1801) Once an employee has been verified through E-Verify by the Employer, the Employer may not create a second case for the employee through E-Venly. a An Employer that is not enrolled in E-Verity as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award arid, within 90 days of enrollment, begin to verily employment eligibility of new hires using E-Verify The Employer must verify those employees who are working in the United States, whether or not they are assigned to the contract. Once the Employer begins verifying new hires such verification of new hires must be initiated within three business days after the hire date Once enrolled in E-Verily as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the dale of enrollment or Within 30 days of an employee's assignment to the contract, whichever date is later Page ol I? F Ve,,Ft ?J010 lo, Errplcyefs J Rcv-sw, 'Dair 06,'01113 a Page 4305 of 7162 E Ver i fy____ Company ID Number: 99%2 b Employers enrolled in E-Verify as a Federal contractor for 90 days of more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire It the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Employer must, within 90 clays of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United Slates, whether or not assigned to the contract Such verification of new hires must be initialed within three business days after the date of hire. An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later c Federal contractors that are institutions of higher education (as defined at 20 U S, C. V)() I state or local governments, govemments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into witty a Federal agency under a performance bond may choose to only verity new and existing employees assigned to the Federal contract Such Federal contractors may, however, elect to verity all new hires, and/or all existing employees hired after November 6, 1986 Employers in this category must begin verification of ernployee,, assigned to the contract within 90 calendar days after the dale of enrollment or within 30 days of an ernployee's, assignment to the contract, whichever date is later c Upon enrollment. Employers who are Federal contractors may elect to verity employment eligibility of all existing employees working in the United States who were hired after November 6, 1986, instead of verifying only those employees assigned to a covered Federal contract After enrollment Employers must elect to verity existing staff following DHS procedures and begin E,Verily verification of all existing employees within 180 days after the election e The Employer may use a previously completed Form 1,9 as the basis for creating an E-Verify case for an employee assigned to a contract as long as I That Form 1-9 is complete (including the SSN) and complies with Article I IA 6, if The employee's work authorization has not expired and iii The Employer has reviewed the Form 1.9 intormaton either in person of in Communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed (including, but riot limited to. a lawful permanent resident afieri, having become a naturalized U.S citizen) f The Employer shall complete a new Form 1-9 consistent with Article It. A 6 or update the previous Form 1-9 to provide the necessary information if I The Employer cannot determine that Form 1-9 complies with Article IVA 6. if The employee's basis for work authorization as attested in Section I has expired of changed of iij The Form 1.9 contains no SSN of is otherwise incomplele NIOR, If Section 1 of Form i.9 is otherwise valid and up-to-date and (tie forin otherwise complies with P49c (of I; F verify IN.),) fo, fmpi*W- tale o6,,ui,i-, 0 Page 4306 of 7162 Company ID Numbitr, 996*2 Article 11 C,5, but reflects documentation (such as a U.S passport or Form 1.551) that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article 11,A,5; subject to any additional of superseding instructions that may be provided on this subject in the E-Verity User Manual g The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that slit is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements C. RESPONSIBILITIES OF SSA I SSA agrees to allow OHS to compare data provided by the Employer against SSA s database SSA sends DHS confirmation that the data sent either matches of does not match the informalion in SSA S database 2 SSA agrees to safeguard the information the Employer provides through E-Verify Procedures SSA also agrees to limit access to such information, as is appropriate by law, to individuals responsible for the verification of Social Security numbers or responsible for evaluation of F -Verify or such other persons of entities who may be authorized by SSA as governed by the Privacy Act (5 U S C § 552a), the Social Security Act (42 U S C 1306(a)), and SSA regulations (20 CFR Part 401) 3 SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry E-Verity provides the information to the Employer 4 SSA agrees to update SSA records as necessary• if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence It the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, it appropriate, within the eight -day period unless SSA determines that more than eight days maybe necessary In such cases, SSA will provide additional instructions Ifithe employee If the employee does not visit SSA in the time allowed, U -Verify may provide a final nonconfirmation to the employer. Note, It an Employer experiences technical problems, or has a policy question, the employer should contact E-Verify at 1-888-464-42 18 D, RESPONSIBILITIES OF DHS I OHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct, to the extent authorized by this MOU a Automated verification checks an alien employees by electronic means, and Psife Yof I I f. verily MOU f0t Errotoyets I Rewsilon Date 06,01113 9 Page 4307 of 7162 h-Verm1fy___&a Company (D Number: O-S962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security iDHS) and the Mitchell & Stark Construction Co, Inc. (Employer) The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E Verrfy. F,Verify is a program that electronically confirms an employee's eligibility to work in the United Statet, after completion of Form 1-9, Employment Eligibility Verification (Form. 1.9) This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA), and DHS Authority for the E -Verify program is found in Tale IV, Subtitle A of the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA). Pub L 104-208, 110 Stat 3009. as amended (8 U S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18. "Employment Eligibility Verification' and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal cunifactor) to use E-Verify to verity the employment eligibility of certain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER 1 The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system a Notice of E-Verify Participation L) Notice of Right to Work 2 T fit Employer agrees to provide to the SSA and DHS the names. titles, addresses, and telephone numbers of the Employer representatives to be contacted about E-Verify The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes 3 The Employer agrees to grant E-Verify access only to current employees who need E -Verify access Employers must promptly terminate an employee's E-Verify access it the employer is separated from the company or no longer needs access to E-Verify rb9t 1 Of ' 7 C,Vet4 MOO 104 Fmt*qtfa I Revs on Date 06,MO 0 Page 4308 of 7162 Ct>mpan) ID Number: 99962 4 The Employe( agrees to become familiar with and comply with the most recent version of The E-Verify User Manual. 5 The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases a The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E -Verify in order to continue using E•Verity. Failure to complete a refresher Tutorial will prevent the Employer Representative from continued use of E -Verity 6 The Employer agrees to comply with current Form 1-9 procedures, with two exceptions a If an employee presents a *List W identity document the Employer agrees to only accept "List G` documents that contain a photo. (List 6 documents identified in 8 C F.R § 274a 2(b)(1)(B)) can be presented during the Form 1-9 process to establish identity ) If an employee objects to the photio, requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218 b If an employee presents a DHS Form 1-551 (Permanent Resident Card), Form 1-766 Employment Authorization Document), or U S Passport or Passport Card to complete Form 1,9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employees Form 1-9 The Employer will use the photocopy to verity the photo and to assist DHS with its review of photo Mismatches That employees contest DHS may in the future designate other documents that activate the photo screening tool Note Subject only to the exceptions noted previously in this paragraph, employees still retain the right to present any List A or List 8 and L,sl C, documeniis) to complete the Form 1-9 7 The Employer agrees to record the case verification number on the employee's Form 1-9 or to print the screen containing the case verification number and attach 0 to the employee's Form 1,9 6 The Employer agrees that, although it participates in E-Verify. the Employer has a responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from otl,wt requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 2748 of the INA with respect to Form 1-9 procedures a The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the INA (1) List 8 identity documents must have photos, as described in paragraph 6 above, (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E -Verify procedures, the Employer establishes 8 rebuttable presumption that it has not violated section 274A(ay 1)(A) of the immigration and Nationality Act (INA) with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that petsuo, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and $1,100 for each failure to notify DHS of continued employment following a final nonconfirmation; (4) It the Employer continues to employ an employee after receiving a final nonconfirmalion, then the Employe( is subject to a rebuttable presumption that it has knowingly i'age 2. it!? IF Vvofy WOO 1W I`MVOyets Revmol Date 0610F I 0 Page 4309 of 7162 Company ID Number: OW9 2 employed an unauthorized alien in violation of section 274A(a)(1)(A)., and (5) no E-Verify participant is civilly of criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b DHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verity. 9 The Employer is strictly prohibited from creating an E-Verify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed The Employer agrees to create an E-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections I and 2 of Form 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual If E -Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate The Employer's attempting in good faith, to make inquiries during the period of unavailability 10 The Employer agrees not to use E -Verify for pre -employment screening of job applicants, in support of any unlawful employment practice or for any other use that this MOU of the E-Verify User Manual does not authorize I I The Employer must use F-Verity lot all new employees The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article 11.8 of this MOU 12 The Employer agrees to follow appropriate procedures (see Article III Wow) regarding tentative nonconfirmations The Employer must promptly notify employees in private of the finding , and provide them with the notice and letter containing information specific to the employee's E-Verify case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding. and not take adverse action against employees if they choose to contest the finding, while their case is still pending Further, when employees contest a tentative nonconfirmalion based upon a photo mismatch, the Employer must take additional steps see Article 1116 below) to contact DHS with information necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DHS is processing the verification request unless the Employer obtains knowledge (a5 defined in 8 C,F R j 274a.1(1)) that the employee is not work authorized, The Employer understands that an initial inability of the SSA or DHS automated verification system to verity work authorization, a tentative nonconfirmation, a case in continuance indicating the need for additional time for the government to resolve a case), of the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employ(-(., is not work authorized In any of such cases, the employee must be provided a full and fait opportunity to contest the finding. and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employees perceived employment eligibility status P09t lol 17 f,Vw,ff* KAOt loY Fm,piovefs ! Rewson uaie o6uwa e Page 4310 of 7162 E-Verify______ sor, Company ID Number 99962 including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued, It the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers or employees with questions about a final nonconfirmation may call 8-Verify at 1-888,464- 4218 (customer service) or 1-888-897-7781 (worker hotline) 14 The Employer agrees 10 comply with Title VII of the Civil Rights Act of 1964 and section 2748 of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his of her national origin or citizenship status or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E -Verify except as provided in part 0 below, or discharging or refusing to hire employees because they appear or sound foreign` or have received tentative nonconfirmations The Employer further understands that any violation of the immigration -related unfair employment practices provisions in section 2748 of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII Gould subject the Employer to back pay awards compensatory and punitive damages Violations of either section 274B of the INA or Title VH may also lead to the termination of its participation in E-Verify. If the Employer has any questions relating to the anti -discrimination provision, it should contact OSC at 1.800-255-8155 or 1-800.237-2515 (TDD) 15 The Employer agrees that it will use the information it receives from E-Verdy only to confirm the employment eligibility of employees as authorized by this MOU The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU except for such dissemination as may be authorized in advance by SSA or DHS for legitimate purposes 16 The Employer agrees to notify DHS immediately in the event of breach of personal information Breaches are defined as loss of control or unauthorized access to E Verify personal data All suspected or confirmed breaches should be reported by calling 1-888464-4218 of via email at E-Veirifv0dhs oov Please use 'Privacy Incident - Password' in the subject line of your email when sending a breach report to E -Verity 17 The Employer acknowledges that the information it receives from SSA is governed by the Privacy Act (5 U S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)). Any person who obtains this information under false pretenses or uses it for any purpose other than as, provided for in this MOU may be subject to criminal penalties 18 The Employer agrees to cooperate with DHS and SSA in their compliance monitoring and evaluation of E -Verify, which includes permitting DHS SSA, their contractors and other agents, upon Wage 4 or 1 r f V-fv MOU to, l-P1-Y&s,, Rewmon Date DbVii;i 0 Page 4311 of 7162 Company l!CiNurribev 99%2 reasonable notice, to review Forms 1.9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verity. and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19 The Employer shall not make any false of unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media The Employer shall not describe its services as federally -approved, federally -certified, or federally -recognized, or use language with a similar intent on its website of other materials provided to the public Entering into this MOU does not mean that E-Verity endorses or authorizes your E-Verify services and any claim to that effect is false 20 Tate Employer shall not state in its websile or other public documents that any language used therein has been provided or approved by OHS, USCIS or the Verification Division without first obtaining the prior written consent of DHS 21 T'he Employer agrees that E-Verify trademarks and logos may be used only under license by DHS/USCIS (see M-795 (Web}) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services. products, wellosiles, of publications are sponsored by, endorsed by, licensed by, or affiliated with DHS USCIS or E -Verify 22 The Employer understands that it it uses E Verify procedures tot any purpose other than as authorized by this MOU. the Employer may be subject to appropriate legal action and termination of its participation in E-Verify according to this MOU B. RESPONSIBILITIES OF FEDERAL CONTRACTORS I It the Employer is a Federal contractor with the FAR E.-Verityclause subject to the employment verification terms in Subpart 22 18 of the FAR, it wit! become familiar with and comply with the most current version of the E -Verify User Manual lot Federal Contractors as well as the E -Verity Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22 18 of the FAR it must verify the employment eligibility of any 'employee assigned to the contract' (as defined in FAR 22 1801) Once an employee has been verified through E-Verity by the Employer. the Employer may not create a second case for the employee through E-Verify a An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, wilhin 90 days of enrollment, begin to verify employment eligibility of new hires using E-Verify The Employer must verify those employees who are working in the United Slat", whether or not they are assigned to the contract Once the Employer begins verifying new hires such verification of new hires must be initiated within three business days after the hire date Once enrolled in E-Verify as a Federal contractor. the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enroitmew or within 30 days of an employee's assignment to the contract. whichever date is later Page I of'? f VeMy Mou for Employers I tit, am#1 Date 0WO 103 0 Page 4312 of 7162 Vorify--a Company ID Number 90-%2 b Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire If the Employer is enrolled in E.-Verity as a Federal contractor for 90 calendar days or lest, at the time of contract award. the Employer must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract Such verification of new hires must be initialed Within three business days after the date of hire. An Employer enrolled as a Federal contractor in E -Verity must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later. c Federal contractors that are institutions of higher education (as defined at 20 US C I Do 1 (a)), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency tinder a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however elect to verity all new hires, and/or all existing employees hired after November 6. 1986 Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employees assignment to the contract, whichever date is later a Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United Slates who were hired after November 6, 1986, instead of verifying only those employees assigned to a Covered Federal contract After enrollment, Employers- must elect to verify existing staff following DHS procedures and begin E -Verity verification of all existing employees within 180 days after the election e The Employer may use a previously completed Form 1-9 as the basis for creating an E -Verify case for an employee assigned to a contract as long as That Form 1-9 is complete (including the SSN) and complies with Article 11 ,A 6 it The employee's work authorization has not expired and fit The Employer has reviewed the Form 1-9 information either it) person or in communications with the employee to ensure that the employee's Section 1, Form 1 -9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U S citizen) I The Employer shall complete a new Form 1•9 consistent with Article If. A 6 or update the, previous Form 1-9 to provide the necessary information 4, t The Employer cannot determine that form i-9 complies with Article 11 A.6, ii, The employee's basis for work authorization as attested in Section 1 has expired or changed, or iir The Form 1.9 contains no SSN or is otherwise incomplete Note If Section I of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies w,th Pige t of I 1 f Ven'y OA>j to, IF mokiyers Re vi!,ivi Wit, 060 I,! 0 Page 4313 of 7162 Company ID Number, 99%2 Article 11 C,5, but reflects documentation (such as a U.S passport or Form 1-551) that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article 11,A.5, subject to any additional or superseding instructions that may be provided on this subject in the E-Verify User Manual 9 The Employer agrees not to require a second verification using E-Verity of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that d it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities unde! this MOU to contracting officers of other officials authorized 10 review the Employer*s compliance with Federal contracting requirements C, RESPONSIBILITIES OF SSA 1. SSA agrees to allow OHS to compare data provided by the Employer against SSA's database SSA sends DH'_- confirmation that the data sent either rnatches or does not match the information in SSA's database 2 SSA agrees to safeguard the information the Emptuyet provides through E-Verify procedures SSA also agrees to limit access to such information as is appropriate by law, to individuals responsible for the verification of Social Security numbers of responsible for evaluation of E -Verify or such other persons or entities who may be authorized by SSA as govemed by the Privacy Act (5 U S C § 552a), the Social Security Act (42 Ul 5 C 1306(a)), and SSA regulations (20 CFR Pall 401) 3 SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry E-Verify provides the information to the Employer. 4 SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence If the employee visits all SSA field office within the eight Federal Government work days from the date of referral to SSA. SSA agrees to update SSA records, if appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary In such cases, SSA will provide additional instructions to the employee, It the employee does not visit SSA in the time allowed, E-Verify may provide a final nonconfirmation to the employer. Note, If an Employer experiences technical problems. or has a policy question, the employer should contact E-Verify at 1.888-464-4218 D. RESPONSIBILITIES OF OHS 1 OHS agrees to provide the Employer with selected data from OHS databases to enable the Fmployer to conduct, to the extent authorized by this MOU. a Automated verification checks on alien employees by electronic means. arid POW 7 01 11 t Vt-14Y MOU fol EnVoyers I Rev-skon DAle 061D I I 3 a Page 4314 of 7162 Company ID Number; 99962 b, Photo verification checks (when available) on employees 2. DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verity. DHS agrees to provide the Employer names, titles, addresses, and telephone numbers of DNS representatives to be contacted during the E-Venty process 3 DHS agrees to provide to the Employer with access to E Verity training materials as well as an E-Verity User Manual that contain instructions on E-Verity policies. procedures and requirements lot both SSA and DHS. including restrictions on the use of E-Verify 4 DEIS agrees to train Employers on all important changes made to E.-Verity through the use of mandatory refresher tutorials and updates to the E-Verify User Manual Even without changes to E -Venfy DHS reserves the right to require employers to take mandatory refresher tutorials 5 DHS agrees to provide to the Employer a notice which indicates the Employer's participation in E-Venfy DHS also agrees to provide to the Employer anti-citiscriminalion notices issued by the Office of Special Counsel for Immigration- Related Unfair Employment Practices (OSC). Civil Rights Division, U S Department of Justice 6 DHS agrees to issue each of the Employer's E-Verify users a unique user identification number and password that permits them to log in to E -Verily 7 DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E-Venfy, or to such other persons or entities as may be authorized by applicable law Information will be used only to verity the accuracy of Social Security numbers and employment eligibility to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements 8 DHS agrees 10 provide a means of automated verification that provides (in conjunction with SSA verification procedures) confirmation or tentative nonconfirmation of employees* employment eligibility within three Federal Government work days of the initial inquiry 9 DHS agrees to provide a means of secondary verification (including updating DHS records) for employees who contest DHS tentative nonconfirmations and photo mismatch tentative nonconfirmal ions This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS. unless DHS determines that more than 10 days may be necessary. In such cases, DHS will provide additional verification instructions ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND OHS A. REFERRAL TO SSA I If the Employer receives a tentative nonconfirmation issued by SSA. the Employer must print the notice as directed by E -Verify The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify r'agk e Of 17 1 VWy KK)U fo, Employers ; Rev1pon r)jne 06r01r13 0 Page 4315 of 7162 Company ID Plumber: 99962 b Photo verification checks (when available) on employees. 2 DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. DHS agrees to provide the Employer names, titles, addresses, and telephone numbers of OHS representatives to be contacted during the E -Verify process 3 DHS agrees to provide to the Employer with access to E4erify training materials as well as an E-Verity User Manual that contain instructions on E-Verify policies. procedures, and requirements for both SSA and OHS, including restrictions on the use of E-Verity 4 DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify Use( Manual Even without changes to E -Verify. DHS reserves the right to require employers to take mandatory refresher tutorials 5 DHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E - Verify DHS also agrees to provide to the Employer anti -discrimination notices issued by the Office of Special Counsel for Immigration -Related Unfair Employment Practices (OSC), Civil Rights Division U S Department of Justice 6 DHS agrees to issue each of the Employer's E -Verify users a unique user identification nurnt*r and password that permits them to log in to E-Verify 7 DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E Verify. or to such other persons or entities as may be authorized by applicable law Information will be used only to verify the accuracy of Social Security numbers and employment eligibi!ity, to enforce the INA and Federa! criminal laws, and 10 administer Federal contracting requirements 8 DHS agrees to provide a means of automated verification that provides (in conjunction with SSA verification procedures} confirmation or tentative nonconfirmation of employees' employment eligibility within three Federal Government work days of the initial inquiry 9 OHS agrees to provide a means of secondary verification (including updating DHS records) for employees who contest OHS tentative nonconfirmations and photo mismatch tentative nonconfirmations This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS, unless DHS determines that more than 10 days may be necessary, In such cases, DHS will provide additional verification instructions ARTICLE III REFERRAL OF INDIVIDUALS 10 SSA AND DHS A, REFERRAL. TO SSA I If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify The Employer must promptly notify employees in private. of the finding and provide them with the notice and letter containing information specific to the employee's E-Verity f'a9c F, 0 17 E Ycri'y MOU fo, frnpwem I Rev,-,V) [Wo 04I0103 C0A, 0 Page 4316 of 7162 E -Verify *. r Company ID Number: 9"62 case The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he of she will contest the tentative nunconfirniation as soon as possible after the Employer receives the tentative nonconfirmation Only the employee may determine whether he or she will contest the tentative nonconfirmation 3 After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed byE-Verdy The Employer must record the case verification number, review the employee, information submitted to F -Verify to identify any errors, and find out whether the employee contests tt)e tentative nonconfirmation The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again it this review indicates a need to do so 4 The Employer will instruct the employee to visit an SSA office vvithw eight Federal Government woo days SSA will electronically transmit the result of the referral to the Employee within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary 5 While waiting for case results, the Employer agrees to check the F-Verify system regularly for case updates 6 The Employer agrees not to ask the employee lociblaina printout from the Social Security Administration number database (the Numident) or other written verification of the SSN from the SSA 8, REFERRAL TO DHS I If the Employer receives a tentative nonconfirmation issued by DHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency 10 employees The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation Only the employee may determine whether he of she will contest the tentative nonconfirmation 3 The Employer agrees to refer individuals to OHS only when the employee chooses to contest a tentative nonconfirmation 4 If the employee contests a tentative nonconfirmation issued by OHS, the Employer will instruct tt* Paqt !. ("I I E ytsity mot j It,, fmrbyrft I Revoo. Wit Wo I, Vj Gl Page 4317 of 7162 Company ID Number 99%2 employee to contact OHS through its toll -free hotline (as found on the referral letter) within eight Federal Government work days, 5 It the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph 1 at this section for tentative nonconfirmations, generally 6 The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1-551, Form 1.766 US Passport, or. passport card to OHS for review by: a Scanning and uploading the document, or b Sending a photocopy of the document by express mail (furnished and paid for by the employer) 7 The Employer understands that it it cannot determine whether there is a photo triatchimismatch, the Employer must forward the employee s documentation to OHS as described in the preceding paragraph The Employer agrees to resolve the case as specified by the OHS representative, who will determine the photo match or mismatch 8 DNS will electronically transmit the result of the referral to the Employer within W Federal Government work days of the referral unless it determines that more than 10 day-, is necessw-y 9 While waiting for case results, the Employer agrees to check the E -Venty system regularly for case updates ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1 SSA and OHS will not charge the Employer for verification services performed under this MOU The Employer is responsible for providing equipment needed to make inquiries To access E-Verity, an F mployer will need a personal computer with Internet access ARTICLE V MODIFICATION AND TERMINATION MODIFICATION 1 This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and OHS operates the, E ..Verity program unless modified in writing by the mutual consent of all parties 2 Any and all E -Verity system enhancements by OHS or SSA, including but not limited to E-Verify checking against additional data sources and instituting new verdicalion policies of procedures, will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes Pikt ,,4t, 10 (,111[ •vtrt!y Moo for F.rrvio*ers Rev soon Dait Da Olt13 0 Page 4318 of 7162 E-Veriwf y ------------ Company ID Number: 99962 employee to contact OHS through its toll -free hotline (as found on the referral letter) within eight Federal Government work days. 5 If the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph I of this section for tentative nonconfirmations, generally. 6 The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1.551, Form 1-766, U S. Passport, or passport card to OHS lot review by. a Scanning and uploading the document, or b Sending a photocopy of the document by express mail (furnished and paid for by the employer) 7 The Employer understands that if it cannot determine whether there is a photo matc h/m is match, the Employer must forward the employee s documentation to DHS as described in the preceding paragraph The Employer agrees to resolve the case as specified by the OHS representative mic will determine the photo match or mismatch 8 OHS will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary 9 While waiting for case results the Employer agrees to check the E Verily system regularly for case updates ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1 SSA and OHS will not charge the Employer for verification services performed under this M00 The Fniployer is responsible for provicl ng equipment needed to make inquiries To access F-Verity, an Employer will need a personal computer with Internet access ARTICLE V MODIFICATION AND TERMINATION A MODIFICATION I This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and OHS operates the E-Verity program unless modified in writing by the mutual consent of ali parties 2 Any and all E -Verity system enhancements by OHS or SSA, including but not limited to E-Verity checking against additional data sources and instituting new verdiralion policies or procedures, will be covered under this MOU and will not Cause the need for a supplemental MOU that outlines these changes PiV 100 17 T Vtl,S WX 110, kmoloY&rs keww" Dale 06:O V1 I a Page 4319 of 7162 IT"", E'Vermify......o", Company ID Numbtt: W%? B. TERMINATION I The Employer may terminate this MOU and its participation in E-Verify at any time upon 30 days prior written notice to the other parties. 2, Notwithstanding Article V, part A of this MOU, DHS may terminate this MOU, and thereby the Employer s participation in E -Verity. with or without notice at any time if deemed necessary because of the requirements of law or policy, or upon a determination by SSA of DHS that there has been a breach of syslery, integrity or security by the Employer, or a failure on the part of the Employer to comply wilt) established E-Verify procedures and/or legal requirements The Employer understands that it 11 is a Federal contractor, termination of this MOU by any party for any reason may negatively affect the performance of its contractual responsibilities Similarly. the Employer understands that it it is in a stale where E-Verify is mandatory termination of this by any party MOU may negatively affect the Employer's business 3 An Employer that is a Federal contractor may terminate this MOU when the Federal contract that requires its participation in E-Ver4 is terminated or completed In such cases, the Federal contractor must provide written notice to DHS If an Employer that is a Federal contractor fail$ to provide such notice. then that Employer will remain an E-Verily participant, will remain bound by the terrns of this KIOU that apply to non -Federal contractor participants, and will be required to use the E-Verity procedures to verity the employment eligibility of all newly hired employees 4 The Employer agrees that E-Verity is not liable for any losses. financial or otherwise, if the Employer is terminated from F. -Verity ARTICLE VI PARTIES A Some of all SSA and DHS responsibilities under this MOU may be performed by contractor(s), and SSA and DHS may adjust verification responsibilities between each other as necessary By separate a( gieeffient with DHS, SSA has agreed to perform its responsibilities as described in this MOU B Nothing in this MOU is intended, or should be construed, to create any right or benefit, substantive of procedural, enforceable at law by any third party against the United States, its agencies. officers, of employees, or against the Employer, its agents, officers, or employees C The Employer may not assign, directly or indirectly, whether by operation of law, change of control of merger, all or any part of its rights or obligations under this MOU without the prior written consent of DHS, which consent shall not be unreasonably withheld or delayed Any attempt to sublicense, assign, or transfer any of the rights, duties, or obligations herein is void D. Each party shall be solely responsible for defending any claim or action against it arising out of or related to E-Verify or this MOU, whether civil or criminal, and for any liability wherefrom, including (but not limited to) any dispute between the Employer and any other person or entity regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by the Employer. E The Employer understands that its participation in F -Verify is not confidential information and may be disclosed as authorized of required by law and DHS or SSA policy, including but not limited to, pa'gir' 71 of I I t Ve-My MOt I for EMvryeft J Rrw's of Dale 06"01,13 0 Page 4320 of 7162 T- Company ID Number; 99962 Congressional oversight, E-Verify publicity and media inquiries, determinations of compliance with Federal contractual requirements, and responses to inquiries under the Freedom of Information Act FOIA) F. The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer and DHS respectively The Employer understands that any inaccurate statement, representation data or other information provided to DHS may subject the Employer, its subcontractors, its employees, or its representatives. to (1) prosecution for false statements pursuant to 18 U S,C 1001 and/or; (2) immediate termination of As MOU and/or; (3) possible debarment or Suspension G The foregoing constitutes the full agreement on this subject between DHS and the Employe? To be accepted as an E-Verify participant, you should only sign the Employer's Section of the signature page, If you have any questions, contact E-Verity at 11.888-464-4218. Flaw I J 0 P t-Vk"N Moil Iw f. ?T,Plo*fs 1 041(, ot)()1,13 0 Page 4321 of 7162 mfyh-Verl Company ID Number, 499t2 Approved by: Mitchell b Stark COnSlrUgrOM Go Inc ame tease Type or Print) title t,attne w J rtti tg Signature baie I EtectroncOy S9nt c 02013r2038 Department of Homeland Security - Ve-attcatietn bivision' rvame triease 1 ype or Nn UsCis veni"Ion Q. tirS Cr i5lgnatU(e Elecuoncai y Sr ryea I agt 13 0 , i E ven`y MOU to, C mptuyers i Rt'.SQ1 bate 0&-01313 Date 02 t W006 0 Page 4322 of 7162 E-Ver1mfy,.,-.* Company 10 Number: 99962 Information Required for the E-Verify Program i relating to your Company'. Mitchell 8 Stark Construdion Co . inc pany Name 170 Wesi First Si Medcra. IN 47260 Company Facility Address PC Box 719 Medora IN 47260 ompany Alternate Address i iCounty or Parish JACKSON lEmployer Identification Number 350%4820 North American Industry Classification Systems Code 237 a rent Company i umber of Employees 1 100In 499 umber of Sites Verified for 2 pas'} 14 of t It Versr-y k".) Ir E mptoy@IS I Rea,I w'. Dale 06 0va5 0 Page 4323 of 7162 lift f ----------- er C—Pany 11) NumWv 99962 Are you verifying for more than I site's If yes, please provide the number of site's verified for in each State: F L' ORI DA I S#1ej5) NVIANA I sde(s) 17 1 VCOY MOU, N! F Vlcyen I Reos*r) Owe Owf)sm 5 0 Page 4324 of 7162 COMPanY 10 Nurmbtt: 99962 Information relating to the Program Administrator(s) for Your Company on Policy questions otoperationalproblems: Ne're Connie sparks Phone Nurnber 812) 966 2151 Fax Nvmtet 812) 966 - 2862 F mad Aadre!,s tsparksprnilcheliSlark Cory, Name 84nOa Burgbachei Phone Number U39) 597 , 2165 ex1 28 Fax Nurnt*, 239) 566 7865 I rna,? Address bburQba,-hei@m tcheiistaq Corn Na'—Oc- Matthew J Helwwj Plvwle NjmDer 812) 966 2151 Pay Numbe, 812) 966 - 2862 Ern3,1 Address Mhewo9m,tctleilstark Corr: Name Ela Caniv,, Phone Number 239) 597 2165 exi 24 Pay Number 239) 566 7865 trnwl Address PcarnPs@rn;jChe1j$ta6. Corr. age 16 01 17 F NN Mau for frnp*yersLert C*'Jo 1! 13 OCA () Page 4325 of 7162 COMP211Y 10 Number qW2 Page intentionally left blank Page, I? of! 7 F Vvty fjM, tor fnpjt),tFj I kewt,0,1 U,ft 06,'O it I i 0 Page 4326 of 7162 2,Q FK,,.IGN _ROFIT CORPORATION ANN IAL'2EPORT DOCUMENT# 845897 Entity Name: MITCHELL & STARK CONSTRUCTION CO„ INC, Current Principal Place of Business: 170 W FIRST STREET MEDORA, IN 47260 Current Mailing Address: P.O. BOX219 MEDORA, IN 47260 FEI Number: 35.0964820 Name and Address of Current Registered Agent: PENNER, BRIAN R 6001 SHIRLEY STREET NAPLES, FL 34109 US FILE© Apr 13, 2020 Secretary of State 8439119228CC Certificate of Status Desired: No The above named entity submits this statement for the purpose of changing its registered offtcc or registered agent, or bath, in the State of Fionda. SIGNATURE: Electronic Signature of Registered Agent Date Officer/Director Detail : Title TREASURER Name HARRISON. FRED C Address 6236 WEST CR 50 NORTH City -State -Zip: MEDORA IN 47260 Title VAS Name SCAFIDI, DAVID C Address 2229 SW 50TH STREET City -State -Zip: CAPE CORAL FL 33914 Title DIRECTOR Name PENNER, JEANNE M Address 6540 HUNTERS ROAD City -State -Zip: NAPLES FL 34109 Title ASST SECRETARY Name PENNER, MITCHELL KEITH Address 6540 HUNTERS ROAD City -State -Zip: NAPLES FL 34109 Title PRESIDENT Name PENNER, BRIAN R Address 6540 HUNTERS ROAD City -State -Zip: NAPLES FL 34109 Title VAS Name WESTHAFER, MICHAEL P Address 4510 PINE ROAD City -State -Zip: FORT MYERS FL 33908 Title ASST. SECRETARY Name SPARKS, CONNIE S. Address 367 E. STATE ROAD 250 City -State -Zip: BROWNSTOWN IN 47220 I hetaof ::e!tiJy trial the iR/Grmaflon Indicated on. 1W rerlan (N sUppJe!nHntH! rHpi)!/ 15 true Hno .ict:urate and ihat My Nki4Y!<i/MC signature shall have the same fegai Hfrect as d made Gllda! oath, that f anion olyleer of dir(rctor of pre corporanorl or it* receiver of frustee er!rpvwoted tc execute this report as required by Clulpfel 607, Ffortda Statute,,; and that my name appeals above, of or; an aftaehment With alt other like ell1polvered, SIGNATURE: BRIAN PENNER PRESIDENT 04/13/2020 Electronic Signature of Signing Officer/Director Detail Date 0 Page 4327 of 7162 Detail by Entity Name Page |of3 oemotl f:,FoCAPO=nONo http://scarch.aunbizoru/ nqoirv/CorporationSeu,ch/SeurchRcsult[eta|?inqui — 6/23/2020 0 Page 4328 of 7162 Detail by Entity Name Page 2 of 3 6540 HUNTERS ROAD NAPLES, FL 34109 Title VAS SCAFIDI, DAVID C 2229 SW 50TH STREET CAPE CORAL, FL 33914 Title VAS WESTHAFER, MICHAEL P 4510 PINE ROAD FORT MYERS, FL 33908 Title Director PENNER,JEANNE M 6540 HUNTERS ROAD NAPLES, FL 34109 Title Asst. Secretary SPARKS, CONNIE S. 367 E. STATE ROAD 250 BROWNSTOWN, IN 47220 Title Asst. Secretary PENNER, MITCHELL KEITH 6540 HUNTERS ROAD NAPLES, FL 34109 Annual Reports Report Year Filed Date 2018 01/10/2018 2019 01 /06/2019 2020 04/13/2020 Document Images 0411312020 -- ANNi1AL REPORT vow Image m PDF format Qi Igg,12G. I 1 --.ANNUAL REPORT View nnage in PDF' format 0111012018 —ANNUAL REPORT[ View image in PDF format 01/06/2017 --ANNUAL REPORT View image in PDF format 02l04120i6 -- ANNUAL REPORT View image in PDF formal Q6/02J2q' ` -- ANNUAL REPORT" View image in Pt)F format 02l24/2014 -- ANNUA!_ REPORT View image in PDF format U6/23120 3 -- ANNU,0.L_REPQRT I View. image: in PDF format 04/2L/2r,122--ANNUAL EEPORT View image; in PDP' fomlat f)2/2512011 --ANNUAL REPORT View image in PDF format 02115/20,10 — ANNUAL REPORT View image in PDF format 0 v, http://search.sunbiz.org/inquiry/CorporationSearch/SearchResultDetaiI?inquirytype=Entity... 6/23/2020 Page 4329 of 7162 Detail by Entity Name Page 3 of 3 0112612CG9 -- ANNUAL REPORT View image in PDF format Q,111 1 f; CO,L+ - ANNI IL R„_„_„ FAT View ,mage in PDfformat 011081200' -- ANNUAL REPORT View image in PDF format 02t031' 0 '8 —ANNUAL REPORT View image in PDF format 01110/ 2005 -- ANNUAL REPORT View image in PDF format 02. 113/2004+— ANNUA.. REPORT ' View image in PDF Format 02/ 03/2003 -. ANNUAL.. REPORT View image in ?LiF format G211 % 12G02 - ANNUAL. REPORT View image in PCJ: fouriat QDR . ZI1! G1?...--./.NNU.A..L tEPQRT Vier image: in PDF format O i25/2GL! --ANNUAL REF!QkT View imago in t'i:ii' format G2727/" 99 ^ -- ANNUAL REIPORT View irr:age i!i i'CiF: format 0210. 511998 -- ANN AL. REPORT View image in PUP format 12/ 04/1497 -- ANNUAL REPORT View image in PDF format Gr/. 711^:. 9_=.ANNLQALRF;E'CJRT, View image in PDF formate 01'./ 1''/1 Q5 -- ANNUL( f2F;i?C i2T View image in PDF format oeca: nnenc of state, e::+ac:, W :-c: p :miens http: // search.sunb iz.orgll nquirylCorporati on S earch/S earchResultDetai 1?inquirytype=Entity... 6/23/2020 Page 4330 of 7162 i M 3 f 4i w c, J u u 0[ Dw CS Ln fry vt 1 w w W d Z U, 0 z z a ¢ n o L O vw V) LL Q Z 00 ry 0 u . t!1 - CI o too a) UJ ON V 00 v p LLJ u c 0 c~n c W LL = ILO LL ® Z S w n- c o W © a w d W _ in 0 a w o m CO U U Z > inELLLLJULU V =< V) C - w w z w p uj0 Q w a _ o G yyp ui TreuR i 4# NIMIIY r 5r E 0 Page 4331 of 7162 EXHIBIT A-3: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Brandon Tripp Josh Peterson Personnel Category Construction Superintendent Project Manager 10 Construction Services Agreement: Revised 072118 (v6) Page 4332 of 7162 Zurich North America Surety lzgg Zurich Way Schaumburg, IL. 6o196 http://www.zurich.com Phones-800-876-z616 Ext4882 317-816-4882 Direct Fax 317-816-4899 E-Mail anthony.ortman@zurichna.com 0 ZURICH July 1, 2020 Collier County Board of Commissioners 3299 Tamiami Trail East, Suite 303 Naples, Florida 34112 RE: BID NO.20-7769 SCRWTP REACTOR TANK 4 BOND NO.9304565 Gentlemen: We are authorizing the issuance of the required Performance and Payment bonds at the request of Mitchell & Starks Construction Co., Inc. The Performance and Payment bonds will be issued undated. Fidelity & Deposit Company of Maryland authorizes Mitchell & Stark Construction Co., Inc. or whomever they designate to date the bonds and the powers -of -attorney once the contract date has been determined. We anticipate that the date will be around July 31, 2020. Since dert i li t Attorney In Fact and Agent Page 4333 of 7162 EXHIBIT B-1: PUBLIC PAYMENT BOND ITB# 20-7769 Bond No. 9304565 Contract No. 20-7769 KNOW ALL MEN BY THESE PRESENTS; That MITCHELL & STARK CONSTRUCTION CO., INC. 6001 SHIRLEY STREET NAPLES, FLORIDA 34109 as Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND , as Surety, located at 1299 ZURICH WAY SCHAUMBURG, IL. 60196 (Business Address) are held and firmly bound to COLLIER COUNTY BOARD OF COMMISSIONERS as Obligee in the SUM Of THREE MILLION EIGHT HUNDRED FORTY-THREE THOUSAND DOLLARS AND NO CENTS ($ 3,843,000.00 _) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of JULY 2020 with Obligee for BID NO.20-7769 SCRWTP REACTOR TANK 4 in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal; Promptly makes payment to all claimants as defined in Section 255.05(9), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of fect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this 4 . day of JULY 2020 , the name of each party being affixed and these presents duly signed by its under -signed representative, pursuant to authority of its governing body. 11 Construction Services Agreement: Revised 072118 (v6) Page 4334 of 7162 Signed, sealed and delivered in the presence of: esses as to Principal STATE OF-- COUNTY OF PRINCIPAL MITCHELL & STARK CONSTRUCTION CO., INC. BY:`__—. NAME: BRIAN PENNER ITS: CEO r z . ":.z.. The foregoing instrument was acknowledged before me by means of 9 physical presence or online notarization, this _I day of 3 -"f 20 ° L; , by of a corporation, on behalf of the corporation. He/she is personall known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: BELINDA BURGBACHER MY COMMISSION # GG 278246 EXPIRES: January 22, 2023 Bonded Thru Notary Public Underwriters AFFIX OFFICIAL SEAL) ATTEST: Wi lrassestd-ISurety REGINA WILLIAMS, ADMINISTRATIVE ASSISTANT nature of Notary Public) NAME !r Legibly Printed) Notary Public, State of f1 Commission No.: G (, .1'tg- .2 Y(— SURETY: FIDELITY AND DEPOSIT COMPANY OF MARYLAND Printed Name) 1299 ZURICH WAY SCHAUMBURG, IL. 60196 11 Bu 7'tZAddressl Authorized Signatu ) ROBERT E. WILLIAMS, JR. ATTORNEY IN FACT Printed Name) 12 Construction Services Agreement: Revised 072118 (v6) At) Page 4335 of 7162 OR n e s Zse:s: STATE OF COUNTY OF As Attorney in Fact Attach Power of Attorney) Printed Name) Business Address) Telephone Number) The foregoing instrument was acknowledged before me by means of 0 physical presence or online notarization, this day of —T 20 , by as Of to , , . ; , ,-t _ a a '. corporation, on behalf of the corporation. He/she is personaU known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: gnature of Notary Public) / Name: &"-Itl Al ! Legibly Printed) AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: III o<aY 9' BELINDABURGBACHER I ? ' MY COMMISSION # GG 278246 EXPIRES: January 22, 2023 rFOF F °c` Bonded Thru Notary Pubiic Underwriters 13 Construction Services Agreement: Revised 072118 (v6) O Page 4336 of 7162 ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"), by ROBERT D. MURRAY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint Robert E. WILLIAMS, JR., of Brownstown, Indiana, its true and lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of the By -Laws of said Companies, and is now in force. IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 1 st day of June, A.D. 2020. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND p SUk, 00;; Q)•aeroryf;sYnt Zy NI..a1MV- li Assistant Secretary Vice President Dawn E. Brown Robert D. Murray State of Maryland County of Baltimore On this Ist day of June, A.D. 2020, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, ROBERT D. MURRAY, Vice President, and DAWN E. BROWN, Assistant Secretary, of the Companies, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that he/she is the said officer of the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. Zi:' •fit aY ,:q tali Constance A. Dunn, Notary Public My Commission Expires: July 9, 2023 POA-F 044-3937A Page 4337 of 7162 EXTRACT FROM BY-LAWS OF THE COMPANIES Article V, Section 8, Attorneys -in -Fact. The Chief Executive Officer, the President, or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys -in -fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney -in -fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at any time. CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Article V, Section 8, of the By -Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney ... Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice -President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this day of 120. 0-1p, c----S(''y It*: x o_ SEAL Brian M. Hodges, Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT ALL REQUIRED INFORMATION TO: Zurich American Insurance Co. Attn: Surety Claims 1299 Zurich Way Schaumburg, IL 60196-1056 Page 4338 of 7162 EXHIBIT B-2: PUBLIC PERFORMANCE BOND IT13#20-7769 Bond No. 9304565 Contract No. 20-7769 KNOW ALL MEN BY THESE PRESENTS: That MITCHELL & STARK CONSTRUCTION CO., INC. 6001 SHIRLEY ST. NAPLES, FL. 34109 as Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND as Surety, located at 1299 ZURICH WAY SCHAUMBURG, IL 60196 Business Address) are held and firmly bound to COLLIER COUNTY BOARD OF COUNTY COMMISSIONERS as Obligee in the sum of THREE MILLION EIGHT HUNDRED FORTY THREE THOUSAND DOLLARS AND NO CENTS 3,843,000.00 ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the - l day of JULY 2020 with Obligee for BID NO. 20-7769 SCRWTP REACTOR TANK 4 In accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Performs the Contract at the times and in the manner prescribed in the Contract; and 2. Pays Obligee any and all losses, damages, costs and attorneys' fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of fect Sureties obligation unde r this Bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this I day of JULY , 20 20 , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 14 Construction Services Agreement: Revised 072118 (v6) Page 4339 of 7162 Signed, sealed and delivered in the presence of esses to Principal STATE OF 1t "tL ^- COU NTY OF PRINCIPAL MITCHELL & STARK CONSTRUCTION CO., INC. In NAME: BRIAN PENNER ITS: CEO The foregoing instrument was acknowledged before me by means of ff physical presence or online notarization, this I day of -1w y 202.: by as of corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did ( did not) take an oath. My Commission Expires: AFFIX OFFICIAL SEAL) G73246 1 EAf',i S. J.t^,;ary 22, 2C 3 1 1a%S=y Vtr rk ignature of Notary Public) r% Name: Legibly Printed) Notary Public, State of: Commission No.: GG V26te2 15 Construction Services Agreement: Revised 072118 (v6) Page 4340 of 7162 ATTEST: 4Witn s Sas to Surety REGINA WILLIAMS, ADMINISTRATIVE AS ISTANT Witness s STATE OF ate,' `` COUNTY OF La ) ) - FIDELITY AND DEPOSIT COMPANY OF MARYLAND Printed Name) 1299 ZURICH WAS SCHAUMBURG, IL. 60196 Bu ' Address) 1Authorized Signatur ROBERT E. WILLIAMS, JR. ATTORNEY IN FACT Printed Name) OR As Attorney in Fact Attach Power of Attorney) rintedName) l Business Address) Telephone Number) The foregoing instrument was acknowledged before me by means of Q5physical presence or online notarization, this I day of w iy 20 6 by of a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: I. iOPJ # GG 273,246 I y i t,lu• Urv'i AFFIX OFFICIAL SEAL) gnature of Notary Public) Legibly Prtnted) Notary Public, State of: Commission No.: 16 Construction Services Agreement: Revised 072118 (v6) 90( Page 4341 of 7162 ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"), by ROBERT D. MURRAY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint Robert E. WILLIAMS, JR., of Brownstown, Indiana, its true and lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of the By -Laws of said Companies, and is now in force. IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 1 st day of June, A.D. 2020. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND SEAL op-z". Assistant Secretary Vice President Dawn E. Brown Robert D. Murray State of Maryland County of Baltimore On this 1st day of June, A.D. 2020, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, ROBERT D. MURRAY, Vice President, and DAWN E. BROWN, Assistant Secretary, of the Companies, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that he/she is the said officer of the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. Constance A. Dunn, Notary Public My Commission Expires: July 9, 2023 POA-F 044-3937A Page 4342 of 7162 EXTRACT FROM BY-LAWS OF THE COMPANIES Article V, Section 8, Attorneys -in -Fact. The Chief Executive Officer, the President, or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attomeys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney -in -fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at anytime." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Article V, Section 8, of the By -Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney ... Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 1 Oth day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice -President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this day of 20 D DEIpy .00'. !si.,4. n. SEAL CO. 3 0ft 0__ Brian M. Hodges, Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT ALL REQUIRED INFORMATION TO: Zurich American Insurance Co. Attn: Surety Claims 1299 Zurich Way Schaumburg, IL 60196-1056 Page 4343 of 7162 EXHIBIT B-3: INSURANCE REQUIREMENTS The Contractor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Contractor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Contractor waive against each other and the County's separate Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Contractor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Contractors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number/contract number and title. The General Liability Policy provided by Contractor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Contractor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Contractor has any self -insured retentions or deductibles under any of the below listed minimum required coverage, Contractor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be Contractor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Contractor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non -renewal on the part of the insurance carrier or the Contractor. The Contractor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or material change in coverage or limits received by Contractor from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Contractor hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 17 Construction Services Agreement: Revised 072118 (v6) Page 4344 of 7162 Should at any time the Contractor not maintain the insurance coverage(s) required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage(s) and charge the Contractor for such coverage(s) purchased. If Contractor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Contractor under this Agreement or any other agreement between the County and Contractor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage(s) purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverage(s) shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Contractor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Contractor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 18 Construction Services Agreement: Revised 072118 (v6) 0 Page 4345 of 7162 Collier County Florida Insurance and Bonding Requirements Insurance / Bond Type Required Limits 1. Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof of exemption. An application for exemption can be obtained online at https://apps,fldfs.com/bocexempt/ 2. Employer's Liability $ single limit per occurrence 3. Commercial General Bodily Injury and Property Damage Liability (Occurrence Form) patterned after the current $ single limit per occurrence, $2,000,000 aggregate for Bodily Injury ISO form Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. Indemnification To the maximum extent permitted by Florida law, the Contractor/Vendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the ContractorNendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. 5. Automobile Liability $ Each Occurrence; Bodily Injury & Property Damage, Owned/Non-owned/Hired; Automobile Included 6. Other insurance as Watercraft $ Per Occurrence noted: United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. Per Occurrence Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Per Occurrence Aircraft Liability coverage shall be carried in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Per Occurrence Pollution Per Occurrence Professional Liability $ Per claim & in the aggregate 1,000, 000 per claim and in the aggregate 2,000,000 per claim and in the aggregate Project Professional Liability $ Per Occurrence Valuable Papers Insurance $ Per Occurrence 19 Construction Services Agreement: Revised 072118 (v6) ED Page 4346 of 7162 Cyber Liability $ Per Occurrence Technology Errors & Omissions $ Per Occurrence 7. Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 9. Consultant shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Consultant shall provide County with certificates of insurance meeting the required insurance provisions. 10. Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. 11. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12. Thirty (30) Days Cancellation Notice required. Consultant's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. Name of Firm Consultant Signature Print Name Insurance Agency Agent Name Date Telephone Number 20 Construction Services Agreement: Revised 072118 (v6) 0 Page 4347 of 7162 EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF (COLLIER) STATE OF (FLORIDA) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: 1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. 2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. 3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. 4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. Witness President Witness STATE OF COUNTY OF CONTRACTOR BY: ITS: DATE: Corporate Seal] The foregoing instrument was acknowledged before me by means of physical presence or online notarization, this day of , 20 by corporation. He/she is personally My Commission Expires: AFFIX OFFICIAL SEAL) as of corporation, on behalf of the known to me OR has produced as identification and did (did not) take an oath. Signature of Notary Public) NAME: Legibly Printed) Notary Public, State of Commissioner No.: 21 Construction Services Agreement: Revised 072118 (v6) Page 4348 of 7162 EXHIBIT D FORM OF CONTRACT APPLICATION FOR PAYMENT Collier County Board of County Commissioners the OWNER or Collier County Water -Sewer Owner's Project Manager's Name: Bid No. Project No. Count 's Division Name Purchase Order No. Submitted by Contractor Representative'. Name Application Date: Contractor's Name & Address: Payment Application No. Original Contract Time: Original Contract Price: Revised Contract Time: Total Change Orders to Date: Revised Contract Amount: Total Value of Work Completed & Stored to Date: Retainage @10% through [Insert Date] Retainage @ 10% through [Insert date] Retainage @ % after Insert date Less Retainage Total Earned Less Retainage Less previous payment(s Percent Work Completed to Date: AMOUNT DUE THIS APPLICATION: Percent Contract Time Completed to Date: Liquidated Damages to Be Accrued Remaining Contract Balance ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. Contractor's Name Contractor's Signature: Date: Type Title: Shall be signed by an authorized representative of the Contractor. to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Payment Professional's Name: Design Signature: Date: to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Payment Owner's Project Manager Name: Si nature: I I Date: 22 Construction Services Agreement: Revised 072118 (v6) Page 4349 of 7162 EXHIBIT D (Continued) SCHEDULE OF VALUES Project Name: Project Number: Date: Period To: ITEM NUMBER DESCRIPTION SCHEDULED VALUE WORK COMPLETED STORED MATERIALS TOTAL COMPLETEE STORED TO DATE PERCENT COMPLETE BALANCE TO FINISH 10% RETAINAGE RETAINAGE reduced rate) TOTAL RETANAGE WITHHELDPREVIOUSAPPLICATIONSTHIS PERIODTHRUDATESINCEDATE TOTALS Explanation for the two columns under Previous Applications: The Thru Date is where you will place all information until the contract is complete unless a release or reduction of retainage issue coi into play. If this happens, all information up to the date of the % change in retainage is placed in the Thru Date column. Information after that date is placed in the Since Date column. This states what has happened since the change in retainage. 23 Construction Services Agreement: Revised 072118 (v6) 9 Page 4350 of 7162 Exhibit D Continued) Stored Materials Record Formula: A+B-C- D=E A B C D E Date Description Supplier Invoice Number Previously Received Received This Period Previously Installed Installed This Period Balance To Install 24 Construction Services Agreement: Revised 072118 (v6) Page 4351 of 7162 EXHIBIT E: CHANGE ORDER An electronic data entry form may be found at: http://bccsr)01/SiteDirectoEy/ASD/Purchasing/Formsl/Forms/Default.aspx Change Order Form Contract : Changer:= Purc.has eOr Contractor!Firm Name: Project Manager Nacre er f: Project;,: Project Name: Department: CrtiEnsl "vni &c2` i«" Crder A,rncunt Original ECC. Appr-+ial Bat=; ^,genes ltar. A Current BCC AprxcvedAmcunt Last BCC Ap.l roval Date; Aaenda Item# Current ConiractANark Qrder Amount SAP Contract Expiration DabE fviastc-) C,Ibr Arnaurtaf this Change ocIWO! T taIChaNe f•cm Or'vjinaI Amount Revise- af-ontract'vr/cO, Ofdet Tutsl 0.3U fCI`,t J: C hangafro mCur;ert 2 C C ApprcvedArXIurt CumulaB-,&-Chen- gf--. 1.^0 C 114'311 ChangefromCurreriArnount e Completion Data, Description of the Tasks} Change, and Rationale for the Change Notice to Proc LI Original Last Approved Revised Date Date Completion Dat Date rofDaysAdded SelectT3sks Add newt3skts) Deletet35k(s:) Ch3ngetask(s) 0 Qther.saesa'o gj Prrvide a responseto thefol6owing: f., detailed and specific explanatiowratiornale of the requested change(s)to the tasks) and ! or the additional days added (if requested;; 2.l why this change was not included in theoriginal contract; and, 3.) describe the impact 0 this change is not processed ...._- ___ .,c _ , f,mna._.- frcmn the Dssigr Prcfessioral a d,or Ca tractor* 6 r__,ec. Prepared by: Date: Frost klarage' Name are Deb+3":m_r2 As«=ptarz of thzs Ctrars r rder she i cQrstit. a m ifo-=stern t r«try r kark ,, .,e, sartiax. zcale a 3 wr<r to s.,bj t tca a.ii t!^e same terms ai crxrdr: crr s as ct rra:re; in t:t a cc•^tract 1 vrork onde ird cafe at«cv=. a5 f,-6iy as f :he 5ama ao=re sta'e' ice, this a captarc e, The ardd;sstmer f. if any. tc t.hf C€ntrata s hsaii c _ s3 ituts a ft:11 s^d tin a! sett iemcn? cf a^-y ar=v ai§ claim s e>i the -Ca^tractor t t«'erv?r ,3 Cons a tiartll rrc=Aing claims for im.a z ar delay costs. Accepted by: Date:. Cont:raclort. rerdorlC_ __,,art D_sibnF'rof_ssrunaar NameofFirm. fpcyec-'appir_able; Approved by: Date: Des,gr F`rcfess v-a': s c °Lsme of Firm, t pro}cct applicatFe; Approved by: D3'e: Pr,x.. remeri Frofessoral 25 Construction Services Agreement: Revised 072118 (v6) 9 Page 4352 of 7162 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. Design Professional's Project No PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER And To Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 26 Construction Services Agreement: Revised 072118 (v6) G Page 4353 of 7162 RESPONSIBILITIES: OWNER: CONTRACTO The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on By: Design Professional Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on 20 OWNER By: Type Name and Title 27 Construction Services Agreement: Revised 072118 (v6) 9 Page 4354 of 7162 EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: Contractor: The following items have been secured by the for the Project known as PO No.: Date: and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner (attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As -Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14. Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: Company Name) Signature) Typed Name & Title) By Design Professional: Firm Name) Signature) Typed Name & Title) By Owner: Department Name) Signature) Name & Title) 28 Construction Services Agreement: Revised 072118 (v6) Page 4355 of 7162 EXHIBIT H: GENERAL TERMS AND CONDITIONS INTENT OF CONTRACT DOCUMENTS. 1. 1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and instal led as part of the Work, whether or not called for by the Contract Documents. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work -site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 29 Construction Services Agreement: Revised 072118 (v6) 9 Page 4356 of 7162 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub -Section 2.2 as the "Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3. 2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be 30 Construction Services Agreement: Revised 072118 (v6) Page 4357 of 7162 limited to the hours of 7 a.m. to 7 p.m., Monday through Saturday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.4 Contractor shall submit its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218. 735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 4.5 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re -submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is 31 Construction Services Agreement: Revised 072118 (v6) Page 4358 of 7162 stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent 50%) completion subject to the guidelines set forth in Florida Statute 255.078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub -subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub -subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non- payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 32 Construction Services Agreement: Revised 072118 (v6) e Page 4359 of 7162 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non -liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5. 3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off -set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 33 Construction Services Agreement: Revised 072118 (v6) Page 4360 of 7162 7. SUBMITTALS AND SUBSTITUTIONS. 7.1 Contractor shal I carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will 34 Construction Services Agreement: Revised 072118 (v6) 0 Page 4361 of 7162 record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub -Contractor's personnel; 8.1.4 The number of Contractor's and Sub -Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1.8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features 35 Construction Services Agreement: Revised 072118 (v6) C AO Page 4362 of 7162 e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The As -Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As -Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material -men, as well as coordinating its Work with all 36 Construction Services Agreement: Revised 072118 (v6) CAO Page 4363 of 7162 work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work 37 Construction Services Agreement: Revised 072118 (v6) e Page 4364 of 7162 Directive. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub -subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent 15%). All compensation due Contractor and any Subcontractor or sub -subcontractor for field and home office overhead is included in the markups noted above. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight 48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pendency of any Claim. 38 Construction Services Agreement: Revised 072118 (v6) CAO Page 4365 of 7162 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit B-3 to the Agreement. 39 Construction Services Agreement: Revised 072118 (v6) 9 Page 4366 of 7162 Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit B-3. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et sea. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet - based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: Commodity based procurement where no services are provided. Where the requirement for the affidavit is waived by the Board of County Commissioners Contractors / Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Contractor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Contractors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the Bidder/Contractor does not comply with providing both the acceptable E-Verify evidence and the executed affidavit the bidder's / Contractor's proposal may be deemed non- responsive. 40 Construction Services Agreement: Revised 072118 (v6) 0 Page 4367 of 7162 Additionally, Contractors shall require all subcontracted Contractors to use the E-Verify system for all purchases not covered under the "Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (E-Verify) program visit the following website: http://www.dhs. gov/E-Verify. It shall be the Contractor's responsibility to familiarize themselves with all rules and regulations governing this program. Contractor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et sea. and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2. 3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies when the Contractor is acquiring permits. Owner will not be obligated to pay for any permits obtained by Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 41 Construction Services Agreement: Revised 072118 (v6) Page 4368 of 7162 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default of the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s) within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials, equipment, supplies, and other items therefore or re -letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 42 Construction Services Agreement: Revised 072118 (v6) 0 Page 4369 of 7162 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below. 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager 43 Construction Services Agreement: Revised 072118 (v6) 9 Page 4370 of 7162 shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch -list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch -list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: 1) Receipt of Contractor's Final Application for Payment. 2) The Release and Affidavit in the form attached as Exhibit C. 3) Consent of surety to final payment. 4) Receipt of the final payment check list. 5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 44 Construction Services Agreement: Revised 072118 (v6) t i f Page 4371 of 7162 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re -inspection fees and costs; to the extent such re -inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight (8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shall as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non -defective Work. Contractor shall bear all direct, indirect and consequential 45 Construction Services Agreement: Revised 072118 (v6) Page 4372 of 7162 costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstructio n. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall 46 Construction Services Agreement: Revised 072118 (v6) Page 4373 of 7162 include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit A-1 is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.6, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight 48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 47 Construction Services Agreement: Revised 072118 (v6) Page 4374 of 7162 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, 48 Construction Services Agreement: Revised 072118 (v6) Page 4375 of 7162 Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5. 7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5. 9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend a pre -construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or 49 Construction Services Agreement: Revised 072118 (v6) 0 Page 4376 of 7162 Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre -construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right -of -Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.net/purchasing. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work ("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of 50 Construction Services Agreement: Revised 072118 (v6) 0 Page 4377 of 7162 the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self -performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub -subcontractor performing any portion of the Work, as well as maintain a log of all such licenses. All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of 51 Construction Services Agreement: Revised 072118 (v6) Page 4378 of 7162 Owner upon termination of Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third -party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its. sub - subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on -site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be caused by Owner or Design Professional or attributable to Owner or Design Professional and including claims based on breach of contract or negligence, shall be an extension of its contract time. 33.6.2 In the event of a change in the work, the Subcontractor's claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus no more than 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub -subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner, and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 52 Construction Services Agreement: Revised 072118 (v6) 0 Page 4379 of 7162 34.1.3 Shop Drawing Submittal/Approval Logs 34.1.4 Equipment Purchase/Delivery Logs 34.1.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 34.1.10 Equipment Costs 34.1.11 Cost Proposal Request 34.1.12 Payment Request Records 34.1.13 Meeting Minutes 34.1.14 Cost -Estimates 34.1.15 Bulletin Quotations 34.1.16 Lab Test Reports 34.1.17 Insurance Certificates and Bonds 34.1.18 Contract Changes 34.1.19 Permits 34.1.20 Material Purchase Delivery Logs 34.1.21 Technical Standards 34.1.22 Design Handbooks 34.1.23 As -Built" Marked Prints 34.1.24 Operating & Maintenance Instruction 34.1.25 Daily Progress Reports 34.1.26 Monthly Progress Reports 34.1.27 Correspondence Files 34.1.28 Transmittal Records 34.1.29 Inspection Reports 34.1.30 Punch Lists 34.1.31 PMIS Schedule and Updates 34.1.32 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the presentation requirements and format. Presentations may include, but not be limited to, the following information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shal I be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County 53 Construction Services Agreement: Revised 072118 (v6) 9 Page 4380 of 7162 under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e-mail DL-FMOPSCa.colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of $500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the Contractor is responsible for all costs. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A "project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid & Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing / will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48-hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials / petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 54 Construction Services Agreement: Revised 072118 (v6) Page 4381 of 7162 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision - making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision -making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 55 Construction Services Agreement: Revised 072118 (v6) Page 4382 of 7162 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS Attached hereto, following this page 56 Construction Services Agreement: Revised 072118 (v6) a Page 4383 of 7162 Exhibit I —Supplemental Terms and Conditions Minimum Qualifications of Bidders Solicitation 20-7769 South County Regional Water Treatment Plant (SCWTP) Reactor #4 Qualification of Bidders: Bidders/Contractors must show experience and successful completion of projects with the construction of Lime Softening Water Treatment Plants (including Clarifiers/Reactor Tanks), and water bearing concrete structures, or similar projects. A. Minimum qualification requirements for General Contractors shall include completion of at least 3 projects in the past ten (10) years, which meet the following criteria: 1. Minimum contract value of $1,500,000. 2. Water or wastewater treatment plant projects. The scope of work for these reference projects shall include either water and/or wastewater clarifiers (including mechanisms with rotating assemblies) in circular reinforced concrete water retaining structures of at the least the size indicated on the drawings. 3. Retrofit, rehabilitation, or improvements completed to an operating water or wastewater facility without unreasonable disruptions to service due to Contractor's actions or failure to act. 4. Work including water retaining structures, gravity and pressure piping systems, site work, structural, mechanical, electrical, and instrumentation work of similar type, size, and complexity. 5. Projects completed and operating to the satisfaction of Owner (to be verified by calling references). 6. Projects completed on time. 7. Projects completed within budget without unreasonable claims or excessive change orders. 8. Proposed project manager and superintendent shall personally have completed projects to meet all criteria listed above as well. B. Any subcontractors selected by Contractor shall have equivalent experience for the trade in which the work will be performed (exclusive of dollar value noted). BIDDERS TO PROVIDE EVIDENCE OF THE ABOVE ON FORM 5 — STATEMENT OF EXPERIENCE OF BIDDER AS FOUND IN THE SOLICITATION DOCUMENT USE ADDITIONAL COPIES OF FORM 5 IF NECESSARY Ow Page 4384 of 7162 ACoRI:> CERTIFICATE OF LIABILITY INSURANCE ATE (MMIDD/Y 7/01/2020YY) F THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 1-317-844-7759 CONTACT NAME: Sherri Abbett AssuredPartners Of Indiana, LLC PHONE FAX No. Ext: 317-595-7361 A/C No: AILADDRESS: sherri.abbett@assuredpartners.com10401N. Meridian #300 INSURERS AFFORDING COVERAGE NAIC # INSURERA:XL INS AMER INC 24554Indianapolis, IN 46290 INSURED INSURERB: STARR IND & LIAB CO 38318 Mitchell & Stark Construction Co., Inc. INSURER C:XL SPECIALTY INS CO 37885 INSURER D: NAUTILUS INS CO 17370 6001 Shirley Street INSURER E: AGCS MARINE INS CO 22837 INSURER F: Naples, FL 34109 COVERAGES CERTIFICATE NUMBER: 59706674 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSRLTR TYPE OF INSURANCE ADDL SUBR WV POLICY NUMBER POLICY EFF MM/DD/YYYY POLICY EXP MM/DD/YYYY LIMITS A X COMMERCIAL G ENERALLIABILITY X CGS740906408 03/01/ 20 03/01/21 EACH OCCURRENCE 1,000,000 CLAIMS -MADE FT]OCCUR DAMAGE To ENTED PREM SES (Ea occur ence) 300,000 MED EXP (Any one person) 10,000 PERSONAL & ADV INJURY 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE 2,000,000 PRO X LODPOLICYIF -JECT PRODUCTS - COMP/OP AGG 2,000, 000 EMPLOYEE BENEFIT 2,000, 000OTHER: A AUTOMOBILE LIABILITY X CAH740002709 03/01/20 03/01/21 COMBINED SINGLE LIMIT Ea accident 1,000, 000 BODILY INJURY (Per person) ANY AUTO OWNED SCHEDULED AUTOS ONLY AUTOSIX BODILY INJURY (Per accident) PROPERTY DAMAGE Per accidentXHIREDXNON -OWNEDAUTOSONLYAUTOSONLY B X UMBRELLA LIAB X OCCUR X 1000584931201 03/01/20 03/01/21 EACH OCCURRENCE 5,000,000 AGGREGATE 5,000,000EXCESSLIABCLAIMS -MADE DED I X RETENTION $ 0 C WORKERS COMPENSATIONEMPLOYERS' LIABILITY Y / N ANYPROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? Mandatory in NH) NIA CWG740002509 03/01/20 03/01/21 X STATUTE OEIIIANDE. L. EACH ACCIDENT 1,000,000 E. L. DISEASE - EA EMPLOYEE 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT 1,000,000 D CPL-PROFESSIONAL CPP201737414 03/01/20 03/01/21 OCC/AGG 5,000,000 E INSTALL -BUILDER'S RISK MZI93015110 03/01/20 03/01/21 2,500 DED/LIMIT 350,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Re: Project description is Bid No 20-7769 SWRWTP Reactor Tank # 4. Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County Included as an Additional Insured Under the Captioned Commercial General Liability and Auto Liability Policies on a Primary Non -Contributory Basis if and to the Extent Required by Written Contract. CERTIFICATE HOLDER CANCELLATION Collier County Board of County Commissioners 3295 Tamiami Trail E. Building C2 Naples, FL 34112 USA SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE 1988- 2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD SABBETT 59706674 Page 4385 of 7162 10401 N. Meridian St., Suite 300 Indianapolis, IN 46290 AssuredPartners Fax: 317-815-6036 or Fax 317-844-9910 of Indiana IF YOU ARE THE RECIPIENT OF THIS CERTIFICATE: ANY WORDING TO PROVIDE ADDITIONAL INSURED COVERAGE, PROVIDE COVERAGE ON A PRIMARY AND NON-CONTRIBUTORY BASIS, OR PROVIDE A WAIVER OF SUBROGATION APPLIES ONLY WHERE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT. CONTRACTUAL LIABILITY COVERAGE IS ONLY PROVIDED TO THE EXTENT SET FORTH IN THE POLICIES AND MAY NOT COVER ALL LIABILITY ASSUMED BY THE NAMED INSURED UNDER THE CONTRACT. IF YOU ARE THE REQUESTOR OF THIS CERTIFICATE OF INSURANCE: AssuredPartners of Indiana, LLC has, upon your request, issued the attached Certificate of Insurance. If you have not already done so, we highly recommend that you provide AssuredPartners of Indiana, LLC with a copy of the insurance and indemnification provisions of the contract pertaining to the Certificate of Insurance request so that we may properly ascertain whether the referenced insurance policies address the limits of insurance, terms and types of coverage required by the contract. While most Certificates of Insurance can be issued at no cost, the contract may require the purchase of additional insurance coverage that could be subject to an additional premium charge. In some instances, the coverage identified in the contract may be outside the underwriting guidelines of the insurance carrier and cannot be obtained. Any contract review performed by AssuredPartners of Indiana, LLC should not be construed as the rendering of legal advice or a legal opinion concerning any portion of the contract. AssuredPartners of Indiana, LLC has not endeavored to identify all potential liability issues that might arise under this contract. This review is provided for information purposes only and should not be relied upon by third parties. Any description of insurance coverage is subject to the terms, conditions, exclusions and other provisions of the policies and any applicable regulations, rating rules or plans. This Certificate of Insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD forms & Policy Cancellation Requirements Effective September 2009, ACORD revised the ACORD 25 Certificate of Insurance and the Acord 27 & 28 Evidence of Property forms, the major change being removal of the cancellation notice provision. Per our contract with ACORD, we are not able to alter pre-existing wording on the current form, nor are we able to complete a proprietary form you provide: Per Indiana House Enrolled Act 1322, effective July 1, 2013, Sec.13. (a) A person is not entitled to notice of: 1) cancellation of 2) non -renewal of; or 3) a material change in; a policy of property or casualty insurance unless the person has notice rights under the terms of the policy of property or casualty insurance or an endorsement to the policy. Violation of this statute is considered an unfair and deceptive act or practice under Indiana Law and if an agent is found to be in violation, they can possibly lose their license, and an insured or customer can possibly be fined. We appreciate your understanding of the legal restrictions on our ability to fully comply with your request. Page 4386 of 7162 SUPPLEMENT TO CERTIFICATE OF INSURANCE o/ DATE ol/aozo NAME OF INSURED: Mitchell & Stark Construction Co., Inc. SUPP (10/ 00) Page 4387 of 7162 COLLIER COUNTY For the Acquisition of Goods and Services Funded By Federal/State Grant Programs Method of Procurement Decision Form PURPOSE: To best determine and document the method of procurement suitable. Classify the procurement situation by ensuring the appropriate conditions below. All elements must apply to use that method. CHECK ONE: Small Purchase Amount <$50,000 (Federal threshold is <$100, 000 —County policy more restrictive. Follow Local Purchasing Policy). Multiple sources available Two or more quotes written/verbal quotes above Micro -Purchase Threshold ($3,000). Grantor agencies require an adequate number of sources for competition under $150,000 - local policy defines the number of adequate sources below.) RANGE INSTRUMENT COMPETITION 0-3,000 Requisition P.O. 1 Verbal Quote 3 000.01-10 000 Requisition P.O. 3 Verbal Quotes 10,000.01-50,000 Requisition P.O. 3 Written Quotes Competitive Procurement Amount >$50,000 (Federal threshold is <$150, 000-- County policy more restrictive. A BCC waiver would be required for informal procurement between $50,000 - $150, 000) Multiple sources available Sealed Bid (IFB) Complete & adequate specs Two or more responsible bidders willing to compete Selection can be made on basis of price Procurement suitable for firm, fixed price No discussion with bidders needed after receipt of offers Competitive Proposals (RFP) Competition specifications not feasible Bidder input needed for specification Two or more responsible bidders willing to compete Discussion needed with bidders after receipt of proposals, prior to award Fixed price can be set after discussion No Cost Plus a Percentage of Cost Contracts (IE—time and material must have ceiling) Sole Source/Noncompetitive (if selected, complete Sole Source Documentation - includes change orders) REQUSITIONED BY: Tami Scott- Project Manager - Bayshore CRA June 22, 2020 est. FY14 v, 3 Page 4388 of 7162 Page 4389 of 7162 Page 4390 of 7162 ATTEST: BOARD OF COUNTY COMMISSIONERS Crystal I 'f&i . :l of Courts COLLIER COUNTY, FLORIDA Cn}Tti• 26.By: =: By:a. 4 : Rick LoCastro, Chairman Dated: / 1 S'A'tt,;Att as to Chairman's signature only App ved as o form and 1 lity: By: Sco .'reach Deputy County Attorney 4110 CAO Page 4391 of 7162 Page 4392 of 7162 Page 4393 of 7162 Page 4394 of 7162 Page 4395 of 7162 Page 4396 of 7162 Page 4397 of 7162 Page 4398 of 7162 Page 4399 of 7162 Page 4400 of 7162 Page 4401 of 7162 Page 4402 of 7162 Page 4403 of 7162 Page 4404 of 7162 Page 4405 of 7162 Page 4406 of 7162 Page 4407 of 7162 Page 4408 of 7162 Page 4409 of 7162 Page 4410 of 7162 Page 4411 of 7162 Page 4412 of 7162 Page 4413 of 7162 Page 4414 of 7162 Page 4415 of 7162 Page 4416 of 7162 Page 4417 of 7162 Page 4418 of 7162 Page 4419 of 7162 Page 4420 of 7162 Page 4421 of 7162 Page 4422 of 7162 Page 4423 of 7162 Page 4424 of 7162 Page 4425 of 7162 Page 4426 of 7162 Page 4427 of 7162 Page 4428 of 7162 Page 4429 of 7162 Page 4430 of 7162 Page 4431 of 7162 Page 4432 of 7162 Page 4433 of 7162 Page 4434 of 7162 Page 4435 of 7162 Page 4436 of 7162 Page 4437 of 7162 Page 4438 of 7162 Page 4439 of 7162 Page 4440 of 7162 Page 4441 of 7162 Page 4442 of 7162 Page 4443 of 7162 Page 4444 of 7162 Page 4445 of 7162 Page 4446 of 7162 Page 4447 of 7162 Page 4448 of 7162 Page 4449 of 7162 Page 4450 of 7162 Page 4451 of 7162 Page 4452 of 7162 Page 4453 of 7162 Page 4454 of 7162 Page 4455 of 7162 Page 4456 of 7162 Page 4457 of 7162 Page 4458 of 7162 Page 4459 of 7162 Page 4460 of 7162 Page 4461 of 7162 Page 4462 of 7162 Page 4463 of 7162 Page 4464 of 7162 Page 4465 of 7162 Page 4466 of 7162 Page 4467 of 7162 Page 4468 of 7162 Page 4469 of 7162 Page 4470 of 7162 Page 4471 of 7162 Page 4472 of 7162 Page 4473 of 7162 Page 4474 of 7162 Page 4475 of 7162 Page 4476 of 7162 Page 4477 of 7162 Page 4478 of 7162 Page 4479 of 7162 Page 4480 of 7162 Page 4481 of 7162 Page 4482 of 7162 Page 4483 of 7162 Page 4484 of 7162 Page 4485 of 7162 Page 4486 of 7162 Page 4487 of 7162 Page 4488 of 7162 Page 4489 of 7162 Page 4490 of 7162 Page 4491 of 7162 Page 4492 of 7162 Page 4493 of 7162 Page 4494 of 7162 Page 4495 of 7162 Page 4496 of 7162 Page 4497 of 7162 Page 4498 of 7162 Page 4499 of 7162 Page 4500 of 7162 Page 4501 of 7162 Page 4502 of 7162 Page 4503 of 7162 Page 4504 of 7162 Page 4505 of 7162 Page 4506 of 7162 Page 4507 of 7162 Page 4508 of 7162 Page 4509 of 7162 Page 4510 of 7162 Page 4511 of 7162 Page 4512 of 7162 Page 4513 of 7162 Page 4514 of 7162 Page 4515 of 7162 Page 4516 of 7162 Page 4517 of 7162 Page 4518 of 7162 Page 4519 of 7162 Page 4520 of 7162 Page 4521 of 7162 Page 4522 of 7162 Page 4523 of 7162 Page 4524 of 7162 Page 4525 of 7162 Page 4526 of 7162 Page 4527 of 7162 Page 4528 of 7162 Page 4529 of 7162 Page 4530 of 7162 Page 4531 of 7162 Page 4532 of 7162 Page 4533 of 7162 Page 4534 of 7162 Page 4535 of 7162 Page 4536 of 7162 Page 4537 of 7162 Page 4538 of 7162 Page 4539 of 7162 Page 4540 of 7162 Page 4541 of 7162 Page 4542 of 7162 Page 4543 of 7162 Page 4544 of 7162 Page 4545 of 7162 Page 4546 of 7162 Page 4547 of 7162 Page 4548 of 7162 Page 4549 of 7162 Page 4550 of 7162 Page 4551 of 7162 Page 4552 of 7162 Page 4553 of 7162 Page 4554 of 7162 Page 4555 of 7162 Page 4556 of 7162 Page 4557 of 7162 Page 4558 of 7162 EXECUTIVE SUMMARY Recommendation to approve Change Order Number 9 to use the remaining allowance funds in the amount of $43,584.67, to increase the total contract price, in the amount of $239,013.17 to $4,082,013.17, add 14 days to the contract, waive liquidated damages in the amount of $1,622,191.00, and authorize payment of Pay Application No. 8 pertaining to Agreement No. 20-7769 for the “South County Regional Water Treatment Plant Reactor Tank 4” project with Mitchell & Stark Construction Company, Inc. (Project No. 70135) OBJECTIVE: To approve Change Order Number 9 to use the remaining allowance funds in the amount of $43,584.67, to increase the total contract price, in the amount of $239,013.17 to $4,082,013.17, add 14 days to the contract, waive liquidated damages in the amount of $1,622,191.00, and to authorize payment of Pay application #8 pertaining to the “South County Regional Water Treatment Plant Reactor Tank 4” project (the “Project”). CONSIDERATIONS: On July 14, 2020 (Agenda Item 11.F), the County entered into Agreement No. 20-7769 (the “Agreement”) with Mitchell & Stark Construction Co., Inc. (“M&S”) for the construction of Reactor Tank No. 4 at the South County Regional Water Treatment Plant (“SCRWTP”). During the construction project, The Board approved change orders for time due to Covid related manpower/personnel availability, industry labor shortages, supply chain issues and shipping delays, as summarized below: · Change Order #4, Board approved 11/09/2021 Item 16.E.8 (added 78 days) · Change Order #5, Board approved 02/22/2022 Item 16.E.3 (added 32 days) · Change Order #6, Board approved 04/12/2022 Item 16.E.4 (added 93 days) · Change Order #7, Board approved 07/12/2022 Item 16.E.2 (added 108 days) · Change Order #8, Board approved 09/27/2022 Item 16.E.11 (added 139 days) Change Orders 4-8 were initiated by staff and ultimately approved by the Board; however, Change Order #6 was executed 16 days after the substantial completion date of February 19, 2022. A summary log of those approvals including contractual stop and start work letters is attached. In those approvals, staff requested that the contract time be extended but did not explicitly request that the time extension sought apply to both the substantial and final completion dates (rather than just the extension of time to the contract), which inadvertently created some confusion as to whether liquidated damages should be applied. While staff’s position is that the Board can retroactively apply the time associated with Change Orders 6-8 contemplated by staff to both the substantial and final completion dates, consistent with staff’s position that liquidated damages had not occurred to date, the Clerk’s office has taken the position that staff did not explicitly and timely process the Change Orders which resulted in the accrual of liquidated damages since February 19, 2022, through the date M&S reached Substantial Completion on November 10, 2023- 629 days. Because staff believes that it had properly and timely processed the previous Change Orders, the County was not actually harmed by any delay; since it was staff’s position that time had been granted extending the then existing Substantial Completion dates. Working cooperatively with the Clerk’s office, staff decided to address the liquidated damages issue by requesting that the Board waive liquidated damages in the amount of $1,622,191.00 (the imposition of which staff doesn’t believe would be appropriate based upon staff’s belief that its processing of the previous Change Orders had extended the Substantial Completion deadline, thus avoiding triggering the commencement of liquidated damages), thereby Page 4559 of 7162 positioning the Clerk’s team to be able to review and process payment of the contractor’s Pay Application #8. In addition, the Project has several pending Work Directives (numbers 5, 12, 18-23) that require a final resolution. As provided in the Agreement at Exhibit H, Section 40, Dispute Resolution, the County requested to meet with M&S to engage in a good faith negotiation to resolve the remaining disputed Work Directive items. County staff met with M&S to negotiate the issues related to the Work Directives on June 14, 2023, August 23, 2023, and September 5, 2023. Of the pending Work Directives in which M&S submitted Time and Material cost sheets, County Staff reviewed and agrees with the Time and Material cost sheet backup provided with respect to Work Directives 18 through 23. The summary of the approved Time and Material costs for work directives 18 through 23 are below: Work Directive Amount WD #18 $ 5,918.75 WD #19 $ 1,282.36 WD #20 $ 2,507.50 WD #21 $ 3,001.61 WD #22 $ 19,268.32 WD # 23 $ 66,587.43 TOTAL $ 98,565.97 After reaching a proposed resolution as to the above Work Directives, subject to Board approval, the County and M&S were left with resolving the two remaining Work Directives in dispute, numbers 5 and 12. County Staff requested and received a cost reasonableness determination from Carollo Engineers, Inc. (“Carollo”) the County’s engineer for this project, which included all costs required to complete the work included in Work Directives 5 and 12 (see attached backup). Ultimately staff and M&S negotiated the costs for Work Directives 5 and 12 during a dispute resolution meeting held on September 5, 2023, subject to Board approval. The final recommended negotiated cost for these two Work Directives is within the cost reasonableness determination provided by the County’s consultant, Carollo. Notably, the total amount for Work Directive No. 5 cost presented by M&S and the cost reasonableness submitted by Carollo Engineer’s is associated with the complete replacement of the effluent piping of Reactors 2 & 3, and installation of effluent piping for Reactor 4. Accordingly, the final negotiated amount for Work Directive No. 5 within the attached Change Order No. 9 includes the total cost less the amount included in the Reactor 4 Schedule of Values, Item 3.11, and the Board approved Work Directive No. 5 amount included in Change Order No. 4. The summary of the negotiated final agreed upon amount for Work Directives 5 & 12 are shown below: Page 4560 of 7162 Work Directive Mitchell & Stark’s Submitted Total Cost Carollo Engineer’s Total Cost Reasonable Determination Amount Less Schedule of Values Item 3.11 - WD#5 Less Change Order No. 4 - WD#5 Amount Carollo Engineer’s Cost Reasonable Adjusted Determination Amount Contractor/County Staff Negotiated Amount - CO#9 WD#5 Amount WD#5 $294,943.74 $262,753.00 $169,000 $53,650 $ 40,103.00 $ 40,103.00 WD#12 $153,928.87 $146,573.00 NA NA $146,573.00 $143,928.87 TOTAL $184,031.87 Change Order Number 9 incorporates the conversion of Work Directives Numbers 5, 12, and 18-23 in the total amount of $282,597.84. Under the Agreement, there is $43,584.67 of remaining Owner’s allowance included in Change Order Number 9 along with an addition of $239,013.17 to the Agreement that effectively converts all pending work directives into the project’s final change order. Change Order Number 9 also includes a contract time extension of 14 days associated with the time to complete the subsurface utility exploration on Work Directive Number 23. Currently the project is in a suspend work status effective October 5, 2023, to preserve contract time. The project will remain in such status pending the Board’s consideration and recommended approval set forth in this agenda item. As part of staff’s request for approval of this item, staff requests that the Board authorize payment on pending Pay Application Number 8, provided that such payment applications are submitted with all required backup documentation establishing the basis for payment required by the Agreement and the backup documentation is acceptable to the Clerk of the Circuit Court & Comptroller. FISCAL IMPACT: The source of funding for the additional $239,013.17 in Change Order #9 is the Water User Fee Capital Project Fund (4012), Project #70135. GROWTH MANAGEMENT IMPACT: There is no impact to the Growth Management Plan related to this action. LEGAL CONSIDERATIONS: This item is approved as to form and legality and requires majority vote for Board approval. -SRT RECOMMENDATION: That the Board: (1) Approve Change Order Number 9 to use the remaining allowance funds in the amount of $43,584.67, increase the total Agreement price, in the amount of $239,013.17 to $4,082,013.17, and to add 14 days to the Agreement. (2) Waive liquidated damages identified by the Clerk’s staff in the amount of $1,622,191.00, since staff had intended to extend the Substantial Completion date by the previous processed Change Orders, and if processed timely, the time to reach substantial completion would not have expired. (3) Authorize payment of pay application Number 8, provided that such payment applications are submitted with all required backup documentation establishing the basis for payment required by the Agreement and the backup documentation is acceptable to the Clerk of the Circuit Court & Comptroller. Page 4561 of 7162 Prepared By: Matthew McLean, Director, Benjamin N. Bullert, P.E. Supervisor - Project Management & Alicia Abbott, Project Manager II, Public Utilities Engineering and Project Management Division Page 4562 of 7162 CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with Mitchell & Stark Construction Co., Inc. ("Contractor") of 6001 Shirley Street, Naples, FL 34109, a Corporation, authorized to do business in the State of Florida, to perform all work ("Work") in connection with South County Regional Water Treatment Plant (SCRWTP) Reactor Tank #4, Invitation to Bid No. 20-7769 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Carollo Engineers, Inc., the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement' and sometimes as the Contract'). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount'), in accordance with the terms of this Agreement: Three Million Eight Hundred Forty -Three Thousand Dollars and 00/100 3,843,000.00 ) Section 4. Bonds. A. If applicable, the Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit B-1 and B-2, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www,fms.treas,gov/c570/c570.html#certified. Should the Contract Amount be less 1 M1kt) Construction Services Agreement: Revised 072118 (v6) , Page 4563 of 7162 than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liauidated Damaaes. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within Three Hundred (300) calendar days from the Commencement Date (herein Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within Thirty (30) calendar days after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, Two Thousand Five Hundred Seventy -Nine Dollars ($2,579.00) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion. The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday 2 Construction Services Agreement: Revised 072118 (v6) Page 4564 of 7162 or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non -delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed upon, attached hereto and made a part of this Agreement for Solicitation 20-7769 "South County Regional Water Treatment Plant (SCRWTP) Reactor Tank #4. Exhibit A-1: Contractor's Bid Schedule Exhibit A-2: Contractor's Bid Submittal Forms and Addendums Exhibit A-3: Contractor's List of Key Personnel Exhibit B-1: Payment Bond Forms Not Applicable Exhibit B-2: Performance Bond Forms Not Applicable Exhibit B-3: Insurance Requirements Exhibit C: Release and Affidavit Form Exhibit D: Contractor Application for Payment Form 3 CpU Construction Services Agreement: Revised 072118 (v6) Page 4565 of 7162 Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions ® Applicable Not Applicable The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 20-7769 "South County Regional Water Treatment Plant SCRWTP) Reactor Tank #4. The complete contract documents, including Addendum with attachments, are available on the County's on-line bidding system: https://www.bidsync.com/bidsync-cas/, which the parties agree comprise the final integrated agreement executed by the parties. Sections corresponding to any checked box ( ® ) expressly apply to the terms of this Agreement and are available through the County's on-line bidding. Exhibit J: Technical Specifications Exhibit K: Permits Exhibit L: Standard Details Exhibit M: Plans and Specifications prepared by Carollo Engineers, Inc. Exhibit N: Environmental Health and Safety Requirements for Construction Projects Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, FL c/o Public Utilities Engineering & Project Management Division 3339 Tamiami Trail East, Suite 303 Naples, Florida 34112-5361 Attn: Alicia Abbott, Project Manager Phone: (239) 252-5344 Email: Alicia.Abbottp_colliercountyfl.gov B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Mitchell & Stark Construction Co., Inc. 6001 Shirley Street Naples, Florida 34109 Attn: Michael P. Westhafer, Vice President Phone: (239) 597-2165 Email: mwesthafer(o-)mitchellstark.com C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. a C fo Construction Services Agreement: Revised 072118 (v6) Page 4566 of 7162 Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)( a) of the Florida Statutes which read as follows: A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreement. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. 5 CA Construction Services Agreement: Revised 072118 (v6) Page 4567 of 7162 Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. 6 010 Construction Services Agreement: Revised 072118 (v6) Page 4568 of 7162 IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s) indicated below. TWO WITNESS FIRST WITNESS Print Naphe SECOND WITNESS r Print Name Date: - ATTEST: CrystaL. K..Kipz0k, Perk of Courts Qom, rller i toG Attes: sto.G a s as t F m andLegality: IV County Attorney Print CONTRACTOR: Mitchell & Stark Construction Co., Inc. By: E 11 Print Name and Title 0 Date 7 tt I`Ll' BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY FLORIDA BY: JL Burt L. Saunders, Chairman 0— Construction Services Agreement: Revised 072118 (v6) ' Page 4569 of 7162 EXHIBIT A-1: CONTRACTOR'S BID SCHEDULE FOLLOWING THIS PAGE) 8 Construction Services Agreement: Revised 072118 (v6) OC Page 4570 of 7162 Solicitation # 20t7769 Solicitation Title SCWTP Reactor Tank #4 Bid Due Date June 4, 2020 @ 3:00 PM BID SCHEDULE Collier County Public Utilities Department Project No. 70135 PROJECT: South County Regional Water Treatment Plant Reactor Tank Number Four iTEM I DESCRIPTION I QUANTITY I UNIT LABEL I TOTAL BASE BID; Includes all items described in the Summary of Work and as shown in the attached Drawings and Specifications with no substitutions or limitations. 1 M BIUZATION (as specified in Section 01,90 90) Not to exceed 3% of the Contract Price per Section 01 20 00 1 LUMP SUM 80,000,00 2 DEMOBILI7AT1QN (as specified in Section 01_20 00,) NW Less than 2% of the Contract Price per Section 01 20 00, 1 LUMP SUM 80,000.00 3 Yard piping 1 LUMP SUM 500,000.00 4 Clear, grubbing, and foundation preparation 1 LUMP SUM 28,000.00 5 Grading and drainage 1 LUMP SUM 90.000.00 6 Lime soft ning reactor 1 6.A Structural Components 1 LUMP SUM 620,000.00 6.B Mechanical Components • Equipment and installation 1 UMP SUM 1,780,000.00 7 Protective coatings 1 i LUMP SUM 110,000,00 8 Electrical 1 LUMP SUM 180,000.00 9 Instrumentation 1 LUMP SUM 30,000.00 10 Calibration of instruments 1 LUMP SUM 5,000.00 11 Startup and trainin 1 LUMP SUM 30,000.00 12 Disinfection 1 LUMP SUM 20,000.00 13 Commissioning 1 LUMP SUM 35,000.00 14 Record drawings 1 LUMP SUM 5,000.00 W___................_ ._.... TRA V EWORK-S r—TTFIf 15 Owner's Allowance (Time & Materials)" $ 1 MATERIAL 250,000 TOTAL Btt3 PRICE 1 $3,$43,000.00 Owners Allowance - for Owners Use as Directed. This Allowance will be used only at the Owner's direction to accomplish work due to unforeseen conditions and/or as directed by the Owner, inclusion of the Allowance as part of the Contract Price is not a guarantee that the Contractor will be paid any portion or the full amount of the Allowance. Expenditures of Owners Allowance will be made through Change Order with proper documentation of Time and Materials supporting the change." NOTES; 1) Failure of the bidder to provide information in ALL of the boxes above may result in the bid proposal being considered non -responsive and rejection of the bid proposal Zero (0) is considered a valid response, but a blank is riot. 0 Page 4571 of 7162 EXHIBIT A-2: CONTRACTOR'S BID SUBMITTAL FORMS AND ADDENDUM FOLLOWING THIS PAGE) 9 Construction Services Agreement: Revised 072118 (v6) Page 4572 of 7162 C: d h r COU ty Acirniristrabve Services DVisK>n Procumesrk nt Serwx—, Date: May 8, 2020 Email: Jini.l~lanagan@colliercountyfl.gov Telephone: (239) 252-8946 Addendum #1 Frorn: Jim Flanagan, Procurement Mangler To: Interested Bidders Subject: Addendum #1 Solicitation 20-7769 SC.:RW'i'P Reactor "Tank #4 flee following clarifications are issued as an addendum identifying the following clarification to the scope of work, changes, deletions, or additions to the original solicitation document for the referenced solicitation: Change 1. Change pre -bid site visit schedule and procedure/scheduling in compliance with COVID 19 1 im itations Remove Instead: In compliance with COVID-19 and CDC recommendations, the non -mandatory site visit will be pre -scheduled for specific times between 9:00 and 11:00a.m. on Thursday May 14 2020, at the ropsect site - SCRWTP, 3851 City Gate Drive, Naples, FL 34117. Contractors are limited to one or two persons only, with a maximum of 4 persons (two contracting firms) per time slot (half an hour increments). Contractors should indicate their interest for a site visit during the non —mandatary pre -bid conference call, and an assigned time will be scheduled for each interested contractor for May 14. Social Distancing practices relative to the COVID-19 pandernic will be imposed during the site visit. The use of a protective mask on all site visitors is encouraged. We would like to start with 2 contractors per time slot, then if there are more than 8 contractors interested in a site visit, a third contractor can be added into each time slot. if there are more than 12 contractors, then another time slot will be added for 11:00 am. Attached Site Visit Seliedule 'Template for reference only If you require additional information please post a question on our Bid Sync (www.bids nc.corn) bidding platform under the solicitation for this protect. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6J4120 Signature) Date Mitchell & Stark Construction Company, Inc. Name of 1" irm) 0 Page 4573 of 7162 00fher C014-11ty Email: Jini.Flatiagan((colliercountyfl.gov Telephone: 239.252.8946AdninistraweSer,ces Dimsion ocuiement ADDENDUM # 2 Date: May 18,2020 Jim Flanagan, Procurement Manager To: Interested Bidders Subject: Addendum # 2 - 20-7769 SCRWIT Reactor Tank #4 This Addendum has been issued for the following items identifying clarifications, changes, deletions, and/or additions to the scope of work, solicitation documents and./or bid schedule for the above reflerenced solicitation: ADDITION: 1. The FDOT Standard Specifications Liquidated Damages schedule will go into effect July 2020. As such, Liquidated Damages for this solicitation is revised from per calendar day to TwO Thousand Five Hundred S,vent Nine dollars t$2,00 per calendar day Reference 20-7769 -, Addendum #1 - l"IX)TI-iquidated Damages rev 07-2020, attached 2. NOTICE: BID OPENING CHANGE OF VENUE: Bid Opening to be held in -person at Procurement Services Conference Room A, 3295 Tamiami Trail East, Naples FL. 34112, and will not be accessible on Procurement Bridge phone. Social Distancing practices and precautions relative to the COVID-19 pandemic will be imposed during this Public meeting. 3. Bidders are reminded to provide all required bid forms and attachments. Reference Bidders Checklist provided in the Solicitation document 4. 20-7769 Pre -Bid meeting Minutes and Sign -in Sheets, attached If you require additional information please post a question on our Bid Sync (w•ww.bLd,- ,,.ygc,co.m) bidding platform under the solicitation For this prqject. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. Signature) Mitchell & Stark Construction Company, Inc. Name of Finn) 6/4/20 Date 0 Page 4574 of 7162 C40' e-r county AdmirisMla ve Services Divsicri Procuremerrt Services Email: Jim.Flanagan(?colliereotirrtyfl.gov Telephone: 239.252.8946 ADDENDUM # 3 Date: May 28. 2020 From: Jim Flanagan, Procurement Manager To: Interested Bidders Subject: Addendum # 3 - 20-7769 SCRWTP Reactor'Tank #4 This Addendum has been issued for the following items identifying clarifications, changes, deletions, and/or additions to the scope of work, solicitation documents and/or bid schedule for the above referenced solicitation: ADDITION: 1.. The FDOT Standard Specifications Liquidated Damages schedule will go into effect July 2020. As such, Liquidated Damages for this solicitation is revised from per calendar day to Two Thousand Five Hundred Seveq!y Nine dolii rs ( .:5. 9,(3tij per calendar day. Reference 20-7769 - Addendum #3 - FDOT Liquidated Damages rev 07-2020,, attached Regarding Bid Opening: ALL RIDS SMALL BE SUBMITTED ELECTRONICALLY ON-LINE VIA BIDSYNC If you desire to attend the Bid Opening meeting to observe the opening of the Electronic Bids as submitted on BidSync, it will be held at Procurement Services Conference Room A, 3295 Tamiami Trail East, Naples FL 34112, and will not be accessible on Procurement Bridge phone. Social Distancing practices and precautions relative to the COVID-19 pandemic will be imposed during this Public meeting. AGAIN, PLEASE NOTE: ALL BIDS SHALL BE SUBMITTED ELECTRONICALLY ON-LINE VIA BIDSYNC 3. Bidders are reminded to provide all required bid forms and attachments. Reference Bidders Checklist provided in the Solicitation document. 4. FORM 5 SHOULD PROVIDE REFERENCES FOR "TANK CONSTRUCTION OR SIMILAR PROJECTS WITHIN THE LAST TEN (10) YEARS AS A JUDC.3E OF ITS EXPERIENCE, SKILL. AND BUSINESS STANDING AND OF ITS ABILITY TO CONDUCT THE WORK AS COMPLETELEY AND AS RAPIDLY AS REQURI D UNDER THE TERMS OFTHE AGREEMENT. Referencing Minimum Qualifications of Bidders per Supplemental Terms and Conditions: Bidders/ Contractors must show experience and successful completion of projects with the construction of Lime Softening Water Treatment Plants (including Clarifiers/Reactor Tanks), and water bearing concrete structures, or similar projects.. A. Minimum qualification requirements for General Contractors shall include completion of at least 3 projects in the past ten (10) years, which meet the following criteria: 1. Minimum contract value of $1,500,000. 2. Water or wastewater treatment plant projects. The scope of work for these reference projects shall include either water and/or wastewater clarifiers (including mechanisms with rotating assemblies) in circular reinforced concrete water retaining structures of at the least the size indicated on the drawings. Two Reference projects shall be in the State of Florida. The third reference project shall be in Florida or a southeast coastal area with atmospheric requirements similar to those of the project 0 Page 4575 of 7162 site (including but not limited to environmental conditions, humidity, weather, groundwater table, wind, and any other specific criteria as outlined in the Florida Building Code). 3. Retrofit, rehabilitation, or improvements completed to an operating water or wastewater facility without unreasonable disruptions to service due to Contractor's actions or failure to act. 4. Work including water retaining structures, gravity and pressure piping systems, site work, structural, mechanical, electrical, and instrumentation work of similar type, size, and complexity, 5. Projects completed and operating to the satisfaction of Owner (to be verified by calling references). 6. Projects completed on time. 7. Projects completed within budget without unreasonable claims or excessive change orders. 8. Proposed project manager and superintendent shall personally have completed projects to meet all criteria listed above as well. B. Any subcontractors selected by Contractor shall have equivalent experience for the trade in which the work will be performed (exclusive of dollar value noted). BIDDERS TO PROVIDE EVIDENCE OF THE ABOVE ON FORM 5 - STATEMENT OF EXPERIENCE OF BIDDER AS FOUND IN THE SOLICITATION DOCUMENT USE ADDITIONAL COPIES OF FORM 5 IF NECESSARY A. Contractor to provide a matrix. 'rhe matrix should include each of these requirements (shown on one axis), and a list of projects (on the other axis). A checkmark (Yes,No) to be used to indicate if the contractor has experience on that regiment for each project listed." 5. 20-7769 Pre -Bid meeting Minutes and Sign -in Sheets, attached SUPPI,EM ENT'Al.. INFORMATION 0. The Subsurface Soil Exploration Analysis and Recommendations - Proposed Reactor'1'ank 4 _. South County Regional Water'l'reatment Plant - Naples - Collier County Florida by Ardaman & Associates, lnc. is attached. 7. 20-7769 - Consolidated Bid Questions and Answers attached. 8. 20-7769 - SUEZ Spec Review Comments. SUEZ provided comments during the bid period to the County which were reviewed by the Engineer and those comments and responses are attached. CONTRACTDOCUMENT'S - SPECIFICATIONS 9. Section 01 11 00 _ Summary of Work Refer to Paragraph 1.07, Qualification of Bidders, and replace it with the following new Paragraph 1.07: 1. Ci7 QUALIFICATIONS OF BIDI)FRS A. Minimum qualification requirements for General Contractors shall include completion of at least 3 projects in the past ten (10) years, which meet the following criteria: Minimurn contract value of $1,500,000, Water or wastewater treatment plant projects. 'i'he scope of work for these reference projects shall include either water and/or wastewater clarifiers including mechanisms with rotating assemblies) in circular reinforced concrete water retaining structures of at least the size indicated on the drawings. ' Two Reference projects shall be in the State of Florida. 1'he third C * it Page 4576 of 7162 reference preject shall be in Florida or a southeast coastal area with atmospheric requirements similar to those of the project site (including but not limited to environmental conditions, humidity, weather, groundwater table, wind, and any other specific criteria as outlined in the Florida Building Code). I Retrofit, rehabilitation, or improvements completed to an operating water or wastewater facility without unreasonable disruptions to service due to Contractor's actions or failure to act. 4. Work including water retaining structures, gravity and pressure piping systems, site work, structural, mechanical, electrical, and instrumentation work of similar type, size, and complexity. S. Projects completed and operating to the satisfaction of Owner (to be verified by calling references). 6. Projects completed on time. 7. Projects completed within budget without unreasonable claims or excessive change orders. 8. Proposed project manager and superintendent shall personally have completed projects to meet all criteria listed above as well. B. Any subcontractors selected by Contractor shall have equivalent experience for the trade in which the work will be performed (exclusive of dollar value noted), C. Contractor to provide a matrix. The matrix should include each of these requirements (shown on one axis), and a list of projects (oil the other axis). A checkmark (Yes/No) to be used to indicate if the contractor has experience on that regiment for each project listed." 10. Section 46 43 54 - Solids Contact Clarifier Equipment Refer to Paragraph 1.04.1), the line titled *'Minimum Detention Tinic in the Reaction Zone at Design 1'reatnient Flow", replace the phrase ->30 minutes" with the phrase ">20 minutes," Refer to Paragraph 1.04.D, the line titled "Weir Loading Rate-, replace the phrase "< 20 gpni!ft2'* with the phrase ->20 gpin/ft." Refer to Paragraph 2.05.13.1, replace the digit "o)"' with the digits "14-. Refer to Paragraph 3.01.A.1, delete this Paragraph and replace the following new paragraph: "I. Field welding is permitted only where indicated on the drawings, this specification, or otherwise approved by the Engineer.** Add new Paraph 2.09.G with the following text: 6. ATyp c "F" valve shall also be provided for the bottom flush assembly as indicate(] on theType Drawings." Add new Paragraph 2.17 with the following text: 2.17 Solenoid Valves A. 3-way solenoid valves: 1 Manufacturers: One of the following or equal: a. ASCO (Automatic Switch Co.), Series 832. B. Design: 1. Valves: Suitable for service under the following conditions: 0 Page 4577 of 7162 a. Fluid water. b. Temperature of fluid: 75 degrees Fahrenheit. C. Piping test pressure: 150 pounds per square inch gauge. 2. Unless otherwise indicated on the Drawings, provide valves that meet the following requirements: a. Minimum NFMA Type 4 enclosure. b. 120 VAC operation, C. Suitable for use as indicated on the Drawings. d. Minimum Class Fcoil insulation. I Famish with openings of size equal to or larger than the nominal size designation of the valve, 4. Furnish with manual/bypass operators. C. Materials: 1. Body: Brass or bronze. 2. Seats: Resilient material. CON'rRACTDOCUMENTS - DRAWINGS: 11. Drawing OOCOI - Bid Set - Site Replace Drawing OOCO I with the attached, revised drawing OOCO I marked Addendum 3. 12. Drawing 000O2 - Bid Set - Yard Piping Replace Drawing O00O2 with the attached, revised drawing O00O2 marked Addendum 3, 13, Drawing OOMOI -Reactor 4 Upper Plan Replace Drawing OOMOI with the attached, revised drawing OOMOI marked Addendum 3. 14. Drawing OOM03 - Reactor 4 Section Replace Drawing OOM03 with the attached, revised drawing OOM03 marked Addendum 3, 15. Drawing OOTMOI -- Mechanical Typical Details Replace Drawing OOTMOI with the attached, revised drawing OOTMOI marked Addendum 3. Ifyou require additional information please post a question on our Bid Si'Wc (wmv.bid.vvnC.(!0 bidding plulfin-in under the Solicitenionftw this project, Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6;14,'2(') Signature) Datc NI i(CIICII ''. S(M k 0',,dkl'WAWII COi, 111C. Name of Firm) ONO Page 4578 of 7162 coiker C014-nty Administrative Services Division Procurement Servr,,es Email: Jim.Flanagan( colliercountyfl.gov Telephone: 239.252.8946 ADDENDUM # 4 Date: June 02, 2020 From: Jim Flanagan, Procurement Manager To: Interested Bidders Subject- Addendum # 4 20-7769 SCRWTP Reactor Tank #4 This Addendum has been issued for the following items identifying clarifications, changes, deletions, and/or additions to the scope of work, solicitation documents and/or bid schedule for the above referenced solicitation: CONTRACT I)OCUMENTS— SPECIFICATIONS: Section 46 43 54 — Solids Contact Clarifier Equipment Refer to Paragraph I .04.G. I. a. I), the line titled "Total Hardness", replace the digits *3 78" with the digits 323,- FORM 5 SHOULD PROVIDE REFERENCES FOR TANK CONSTRUCTION OR SIMILAR PROJECTS WITHIN THE LAST TEN (10) YEARS AS A JUDGE OF ITS EXPERIENCE, SKILL AND BUSINESS STANDING AND OF ITS ABIL.ITY TO CONDUCTTHE WORK AS COMPL. ETELEY AND AS RAPIDLY AS REQURED UNDER. THE TERMS OF -11413 AGREEMENT, Referencing Minimum Qualifications of Bidders per Supplemental "Penns and Conditions. BIDDERS TO PROVIDE EVIDENCE OF THE ABOVE ON FORM 5 — STATEMENT OF EXPERIENCE OF BIDDER AS FOUND IN THE SOLICITATION DOCUMENT USE ADDITIONAL COPIES OF FORM 5 IF NECESSARY Contractor to provide a matrix. The matrix should include each of these requirements (shown on one axis), and list of projects (on the other axis). A checkmark (Yes/No) to be used to indicate if the contractor has experience on that regiment for each project listed." Bidders are reminded to provide all required bid forms and attachments. Reference Bidders Checklist provided in the Solicitation document. Bid Due is unchanged: Bids due on-line in BidSync no later than Thursday May 4..2020 (w 3:00pat Ifyou require additional inft)rmationplease post a question on our did Sync (Wvq.%h...sv.n.C..C.o.m bidding undei the Solicitationfi)r this protect. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 614/ 20 Signature) Mitchell & Stark Construction Company, .Inc. Narne of Finn) Date 0 Page 4579 of 7162 Director, Procurement Services Division FORM I - BID RESPONSE FORM BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA South County Regional Wat.er'Freatment Plant (,SC.'RWTP) Reactor `Wank #4 BID NO.20-7769 Dull Name of Main Business Address Mitchell & Stark Construction Company, Inc. 6001 Shirley Street, Naples. FL. 34109 Place of Business Same Telephone No. 239- 597-2165 Fax No State Contractor's License # C GC058926 239- 332-2819 State of Florida Certificate of Authority Document Number 845897 Federal Tax Identification Number35- 0964820 DUNS h C'CR _ Cage Code To: BOARD OF COUNTY COMMISSIONERS OFF COLLIER COUNTY, FLORIDA hereinafter called the Owner) The undersigned, as Bidder declares that the only person or parties interested in this Bid as principals are those named herein, that this Bid is submitted without collusion with any other person, firm or corporation; that it has carefully examined the location of the proposed Work, the proposed form of Aereement and all other Contract Documents and Bonds. and the Contract Drawings and Specifications. Bidder proposes. and agrees if this Bid is accepted, Bidder will execute the Agreement included in the Bidding Documents.. to provide all necessary machinery, tools, apparatus and other means of construction, including utility and tratisportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract, and to do all other thinks required of the Contractor by the Contract Documents, and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points, and in the case where further decimal points are inadvertently provided, rounding, to two decimal points will be conducted by Procurement Services Division staff, Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement forth attached to the Bidding documents within ten (10) calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents. The bid security attached is to become the property of the Owner in the event the Agreement, Insurance Certificates and Bonds are not executed and delivered to Owner within the time above set forth, as liquidated damages, for the delay and additional expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period, In the event of such failure, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it faits to execute and deliver the Agreement, Insurance Certificates, and Bonds as required hereunder. The Constttaction Solicitation Doc rev 02-21-20 C to Page 4580 of 7162 Successful Bidder hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty. which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely manner. Upon receipt ol"the signed and approved agreement and Purchase Order, the undersigned proposes to commence work at the site within five (5) calendar days from the commencement date stipulated in the written Notice to Proceed unless the Project Manager, in writing, Subsequently notifies the Contractor of a modified (later) commencement dale. The undersigned further agrees to substantially complete all work covered by this Bid within Three 11undred (300) consecutive calendar days, computed by excluding the commencement date and including the last day of'such period, and to be fully completed to the point of final acceptance by the Owner within Thirty (30) consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. Acceptance and acknowledged by an Authorize Agent Signature: Title: Vice President 6/4/20 Date: Construction Solicitation Doc rev 02-21-20 OCINO Page 4581 of 7162 FORM 2 -CONTRACTOR'S KEY PERSONNEL ASSIGNED TO TUE PROJECT South County Regional Water Treatment Plant (SCRW`TP) Reactor Tank 44 Bid No. 20-7769 Nam Brandon Tripp Josh Peterson Construction Solicitation Doc rev 02-21-20 Personnel Cq!Moa, Construction Superintendent ProJect KUnager Page 4582 of 7162 FORM 3 - MATERIAL MANUFACTURERS THIS FORM MUST BE COMPLETED OR BID SHALL BE DEEMED NON -RESPONSIVE All Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this Bid specifications, including; compliance with Florida Statute 255.20 to provide lumber, timber and other forest products produced and manufactured in the State of Florida as long, as the price, fitness and quality are equal. Exceptions (when equals are acceptable) may be requested by completing the ;Material Manufacturer Exception List below. if an exception for a manufacturer and>or material is proposed and listed below and is not approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in the specification. Acceptance of this form does not constitute acceptance of material proposed on this list. Complete and sign section A OR B. Section A (Acceptance of all manufactures and materials in Bid specifications) On behalf of my firm, I confirm that we will use all manufacturers and materials as specifically outlined in the Bid specifications. Company: Mitchell & Stark Construction Company, Inc. Signature: '"'" "` W...... Date: 6/4120 Section B (Exception requested to Bid specifications manufacturers and materials) EXCEPTION IGMATF.RIAL EXCEPTIC N .MANUFACTURER 4, Please insert additional pages as necessary. Company: Mitchell & Stark Construction Company, Inc. Signature'_ Date 6/4/20 Construction Solicitation Doc rev 02-21-20 0 Page 4583 of 7162 FORM 4 - LISTOF MAJOR SUBCONTRACTORS THIS t,isT MUST BE COMPLETED OR BID MAYBE DEEMED NON -RESPONSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories outlined in the requirements of the )aid specifications. The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the major categories listed herein are "qualified" (as defined in Ordinance 2017-08 and Section 15 of Instructions to Bidders) and meet all legal requirements applicable to and necessitated by the Contract Documents, including, but not limited to proper licenses, certifications. registrations and insurance coverage. The Owner reserves the right to disqualify any Bidder who includes non -compliant or non -qualified Subcontractors in its bid offer. Further. the Owner may direct the Successful Bidder to remove/replace any Subcontractor, at no additional cost to Owner, which is found to be non -compliant with this requirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents, the Successful Bidder shall identify all Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified as noted above. Major Category of Work Subcontractor and Address I , _ Concrete 1 c , r: >'t 2. Reactor Structural Components I r. Ise 1r 1, 3. Reactor Mechanical Components_ 4, Protective Coatings 5, Sitework fol,1 I6. Underground Utilities 1 7 'tlr_ 1_ --, T Mechanical Je,Ir" ! r , 8 Electrical ia;f d" 9. Identify other subcontractors that represent more than 10% of price or that affect the critical path of the schedule Cotnpany: Mitchell & Stark Construction Company, Inc. Signature: Date: 614120 Construction Solicitation Doc rev 02-21-20 0 Page 4584 of 7162 FORM 5 - STATEMENT OF EXPERIENCE OF BIDDER The Bidder is required to state below what work of similar magnitude completed within the last five ("5) years is a judge of its experience, skill and business standing and of its agility to conduct the work as completely and as rapidly as required under the terms of the Agreement. Babcock Ranch TCU project name) Charlotte Coons. F 1prida,, project location) WTP &_WWTP project description) 2t71h.7t)t7 . 1 4 00 ).O( project starCcompletion dates) (contract value) Babcock lunch Infrastruture project name) Charlotte „Counter Florida......._ . project location) Site Dc ek> mcnt _Uncier;rc unciUtiiitics____ project description) W } it gn,& Pr, -41L . . project owner} — ..._. __ _. 14750 SR 11, Punta Gnrdtt Flc7r da 33if12„ Owner' s address) John Broderick Vice „President Owner' s contact person) (title.) 441- 235-6907 com.._ phone) ( email) Kitson & Partners project owzter) 14750 S!2 31s.Punta C,«rdit 11t rrda.3398, Owner' s address) avid Mercer.,, .. P-.M.la. t Ma_ .,?a..ger. Owner' s contact person) (title) 2016; 20I8 _._......__.__ $,3i.000.U(3„ 239-567-5159 __. drticrca k >M)....t...... ;ratrx project stamcomplet ion dates) (contract value) (phone) (email) Pine Island,WWTP, lnYvrovements-,......__ .... project name) f' intw Island, Florida _ project location) e C;aunt_U iht rs...__ _.__ ..__.__. ,,, project owner) Port Myer, Owner' s address) titiAkP L'xpansion & Improvement,Mikes Maillakakis PE Proiect Mana v project description) ( Owner's contact person) (title) 1_, -21- 2 __. project starVcompletion dates) (contract value) 239-533- 8845.. a'unaillakakt si'Icc,1trti,.t7Jrrtt phone) (entail) Construction Solicitation Doc rev 02-21-20 c Page 4585 of 7162 FORM 5 - STATEMENT OF EXPERIENCE OF BIDDER 4, North Lee RO Expansion project name) North Fort Myers, FL project location) WTP Expansion project description) 10r2011 S 18,500,000 project completion date) (contract value) 5, NCWRF ASHT/r_Q3 Tank project name) Naples, FL. project location) WWTP EQ Expansion project description) 122014 S 5,902,000 project completion date) (contract value) 6. Gateway WWTP project name) Lee County. FL. project location) 2 MGD WWTP Expansion project description) t 112010 S 27,600,000 project completion date) (contract value) Lee County Utilities project owner) Fort Myers, FL Owner's address) Mikes Maillakakis Project Manager Owner's contact person) (title) — 239-533-8845 mmaillakakis(e leegov.com Phone),.,_._.—__ . (email)..,_._..____ _...__. C'ollierCounty BoC:'C project owner) 3299 Tamiami 'Nail East, Naples, Fl.. 34112 Owner's address) Pete Schalt Project 'Manager Owner's contact person) (title) 239- 252-5343 Peter.Schalt(q;cotliereountyil.gov phone) (email) Lee County Utilities project owner) Fort Myers, FI. Owner's address) Mikes Maillakakis Project Manager Owner's contact person) (title) 239- 533-8845 mmaillakakis(irrleegov.com phone) (email) Company: Mitchell & Stark Construction Company, Inc. PY _ ....._._......._.............._.._..._..___.............._....._._...__.__...__._._.._ ____....._.._.._. _. - 6t4/20 Signature: Construction Solicitation Doc rev 02-21-20 a Page 4586 of 7162 M Page 4587 of 7162 FORM 6 - TRENCH SAFETY ACT Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of lorida) effective October I, 1990, The Bidder further identifies the cost to be summarized below: French Safety Units of' Unit Unit Extended Cost Measure Measure (Quantity) cost Me-S.rjpfi.on) (IMF SY) IVV30 k (P<00 TOTAL $_ k Failure to complete the above may result in the Bid being declared non -responsive. Company Mitchell & Stark Construction Company, Inc. I.......... . ... . . ........... ..... Signature: . . . ... .... ..... Date. 6,14120 Construction Solicitation Doc rev 02-21-20 0 Page 4588 of 7162 EY3RlbI7-BIDBONDBUND_..... ._..... .... .... _., KNOW ALI. MEN BY THESE PRESENTS, that we MITCHELL&STARK CONSTRUCTION Ca., INC, (herein after called the Principal) and FIDELITY AND DEPOSIT COMPANY OF MARYLAND (herein called the Surety), a corporation chartered and existing under the laws of the State of MARYwND with its principal offices in the city of eALTIMORE and authorized to do business in the State of FLORIDA are held and firmly bound uftto the COLLIER COUNTY BOARD OF COMMISSIONERS (hereinafter called the Owner), in the full and just sum of FIVE 17046EN4'4'TimiE MAXIMUM 8 AMOLINT dollars ($ 5% I good and lawful money of the United States of America, to be paid upon demand of the Owner, to which payment well and truly to be made„ the Principal and the Surety bind themselves, their heirs, and executors, administrators, and assigns, jointly and severally and firmly by these presents. Whereas, the Principal is about to submit, or has submitted to the Owner, a Bid for furnishing all labor, materials, equipment and incidentals necessary to furnish, install, and fully complete the Work on the Project known as Bid No. 20- 7769.South County Regional Water Treatment Plant (SCRWTP) Reaetor Tank 44. NOW, TIDEKEFORE, if the Owner shall accept the Bid of the PRINCIPAL and the PRINCIPAL shall enter into die required Agreement with the Owner and within ten days after the date of a written Notice of Award in accoillance with the terms of such Bid, and give such bond or bonds in an amount of f 00% the total Contract Amount as specified in the Bidding Documents or Contract Documents with good and sufficient surety for the faithful pertorinance ofthe Agreement and for the prompt payment of labor, materials and supplies furnished in the prosecution thereof or, in the event of the failure of the PRINCIPAL. to enter into such Agreement or to give such bond or bonds, and deliver to Owner the required certificates of insurance, if the PR.INCPPAI.. shall pay to the OBI..IfiEE the fixed sum of S sx noted above as liquidated damages, and not as a penalty, as provided in the Bidding Documents, then this obligation shall be null and void. otherwise to remain in full force and effect. IN TD STIMONY Thereof, the Principal and Surety have caused these presents to he duly signed and sealed this 4TII__ . day of JUNE 2020 MIICHELL & 5TARK CONSTRUCTION CO., INC,Principal BY Seal) BRIAN PENNER. CEO j jar ,VS 'A 4L F10EL r?Y /4 j15 O `OSIT COMPANY of MARYt.AND Surety Seal) f2 Stir E s6r tAdvt3, JR ATTOPM' Y-SN FACT Countersigned Appointed Producing Agent for 00 Page 4589 of 7162 ZURICI I AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AN'D DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW,'V-L MEN DY'llff"Sl: PRESEN,rs:'Thai the ZURICII AMERICAN INSURANCE COMPANY, a corporation of the Suitt: of New York, the COLONIAL AMERICAN CASUALTY AND SLW,,.TY COMPANY, a corporation of the State of Illinois, and the FIDE11TY AND DEPOSITCOMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"). by ROBERT D. MURRAY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, arid appoint Robert F. WILLIAMS, JR., fill'Brownstown, Indiana, its true and lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as surety and as its act and deed: any and all bonds and undertakings, and the execution of sitch bonds or undertakings in pursuance of these presents, shall he as bindifig upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZUR ICB AMERICAN INSURANCE COXfPANY at its office in New York, New York., the regularly elected officers of the COLONIAL: AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Mnryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY 01' MARYLAND at its officc in Owings Mills. Maryhutd,, in their own Proper Persons. the said Vice President does hereby certity that th,, extract set forth on the reverse side hereof is a true copy of Article V, Section 8, oi' the By-1,aws of sail Companies, and is now in force. IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed hivbcr natnes and affixed the Corpoiate Seals of the stud ZURIC 11 AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, arid FIDEL) TV AND DEPOSIT COMPANY OF MARYLAND, (tits 2)1h day ot'July, A.D. 2019. ATTEST,. ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURE't V COMPANV F111. 41XI'VAM) IwPosry cOMPANY OF MARYLAND W P. N BY-, . ................. ............ ......................... . ......... ...... Assis- fant,Secrelaty Vice President Dawn E Brown Ron etf D. Murray State o(Mat, viand County of Baltimore On this 21Ah day of.fuly, A D. 2019, before the subscriber, a Notary Public of the Stale of Maryland, duly commissioned and qualified, ROBVRI I). NIVRRAY, Vice President, 2nd DAINN E, BROWN, Assistant Secretary, of the Companies, to me personally knowi to he the individuals and officers described in and who ex"uted the preceding instrument, and acknoMcdgcd the execution of same, and being by me duly sworn, dcpowth and saith, that he/ she i< the said officer of the Company aforesaid, and that the seals affixed to the, preceding instrument are the Corporate Seals of said ( i 'onipam", and 1141 the said Coriforatc, Seals and the signature as such offioa were duly affixed and stjbsczibcd to the said instrument by the authority and direction of the said Cut porai',014 INTESTIMONY WHERLOF, I have licitunto set my hand and affixed my Official Seat the day and year first aluive wrincti, My Cwrfrnisston Expires, July 9, 2C23 POA- F 044-3937A Page 4590 of 7162 FORM INSURANCE AND BONDING REQUIREMENTS The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in FORM 8 of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Vendor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf' of Collier County", or, the specific solicitation number and title. The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County. Florida. as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in FORM 8 with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Vendor has any self - insured retentions or deductibles tinder any of the below listed minimum required coverage, Vendor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be Vendor's sole responsibility. Covcrage,(sJ shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer, The Vendor and,or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non -renewal on the part of the insurance carrier or the Vendor. T'he Vendor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non - renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder. Vendor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverageUs required herein. the County Ina)' terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage Ds and charge the Vendor for such coverageLb) purchased, If Vendor fails to reimburse the County lor such costs within thirty (30) days after demand. the County has the right to offset these costs from any amount due Vendor under this Agreement or any other agreement between the County and Vendor. The Countyounty shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverageW purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverageW shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope orwork, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s) shall be considered justification fi)r the County to tenninate any and all contracts. 0 Page 4591 of 7162 Collier County Florida Insurance and Bonding Requirements Insurance / Bond Ifype Required Limits 1, Z Worker's Compensation Statutory I-imits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprictorships shall not be required to provide a proof of exemption. All application for exemption can be obtained online at IMps-.8a p,,fl, fs.comlbocexempt/ 2. Z Employer's Liability $1,000,000 single limit per occurrence 3, Z Commercial General Bodily Injury and Property Damage Liability (Occurrence Fonn) patterned after the $1,000,000 single limit per occurrence, $2,000, 000 aggregate for Bodily Injury current ISO form Liability and Property Damage I iability, This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4, Z Indemnification To the maximum extent permitted by Florida law, the Contractor Vendor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabiflifics, damages, losses and costs, including. but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor/ Vendor or anyune employed or utilized by the Contractor 'Vendor in the performance of this Agreement. 5. Z Automobile Liability 51,000,000 Each Occurrence, Bodily Injury & Property Damage. Owned'Non-owned4-fired; Automobile Included G. Z Other insurance as El Watercraft S,,,.............._.........._.._.Per Occurrence noted: El L.Jnited States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. S Per Occurrence Fj Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work, Per Occurrence Aircraft Liability coverage shall be carried in limits of not less than 55,000,000tr each occurrence if applicable to the completion of the Services under this Agreement. Per Occurrence Pollution $ 1,000,000 Per Occurrence E] Professional Liability Per claim & in the aggregate Project Professional Liability S .......... I ........... Per Occurrence Valuable Papers Insurance S Per Occurrence EJ Cyber Liability Per Occurrence M Technology Errors & Omissions Per Occurrence 0 Page 4592 of 7162 7. Z Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of eredit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. ® Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving; award, and written for 100%of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 9. ® Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. I'he same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. 10. JE Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. 'I his insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Vendor's policy shall be endorsed accordingly. I I . ® The Certificate Holder shall be named as Collier County Board of County Coin inissionets, OR. Board of County Commissioners in Collier County, OR Collier County Government. OR (:Iollier County. The Certificates of Insurance must state the Contract Number, or Project Number. or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12, Z On all certificates, the Certificate Bolder must read: Collier County Board of Commissioners. 3295 Tamiami Trail East, Naples, FL 34112 13, Z Thirty (30) Days Cancellation Notice required. 14. Collier ('ounty shall procure and maintain Builders Risk Insurance on all constriction projects where it is deemed necessary. Such coverage shall be endorsed to cover the interests of Collier County as well as the Contractor. Premiums shalt be billed to the project and the Contractor shall not include Builders Risk premiums in its project proposal or project billings. All questions regarding Builder's Risk Insurance will be addressed by the Collier County Risk Management Division. 4r27120 - CC Vendor's Insurance Acceptance By submission of the bid Vendor accepts and understands the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. The insurance submitted must provide coverage for a minimum of six (6) months front the date of award. 0 Page 4593 of 7162 Coiler Comiq Administrative Services Department Prrn:v e,mont senOr$15 ",*""'F,wn FORM 9 - CONFLICT OF (NURFsi, AFFIDAVIT I'tte Vendor certifies that, to the best of its knowledge and belief, the past and current work on any Collier County project affiliated with this solicitation does not pose an organizational conflict as described by one of the three categories below: Biased ground rules — The firm has not set the "ground rules" for affiliated past or current Collier County project identified above (e.g.. writing a procurement's statement of' work, specifications, or performing systems engineering and technical direction for the procurement) which appears to skew the competition in favor of my Finn. Impaired objectivity — The firm has not performed work on an affiliated past or current Collier County pro ject identified above to evaluate proposals % past performance of itself`or a competitor, which calls into question the contractor's ability to render impartial advice to the government. Unequal access to information —The firm has not had access to nonpublic information as part of its performance of a Collier County project identified above which may have provided the contractor (or an affiliate) with an unfair competitive advantage in current or future solicitations and contracts. In addition to this signed affidavit, the contractor I vendor must provide the following: I , All documents produced as a result of the work completed in the past or currently being worked on for the above - mentioned project; and, 2. Indicate if'the information produced was obtained as a matter of public record (in the "sunshine' or through non- public ('not in the "sunshine") conversation (s). mecting(s). document(s) and or other means. Failure to disclose all material or having an organizational conflict in one or more of the three categories above be identified, may result in the disqualification for future solicitations affiliated with the above referenced project(s). By the signature below. the firm (employees, officers and`or agents) certifies,. and hereby discloses, that, to the best of their knowledge and belief, all relevant facts concerning past. present, or currently planned interest or activity financial, contractual, organizational, or otherwise') which relates to the project identified above has been fully disclosed and does not pose an organizational conflict. Mitchell K Stark Construction Company, Inc, Cot7tpany Name Si matureMichaelP. Westhafer, Vice Presidenp 1. .............. _ . _ .........1.11111 Print name. and Title State of Florida Couruy of Lee The foregoing instrument was acknowledged before me by means of 0 physical presence or iJ online notarization, this 4th day of June (month), ^2020(year). by Michael P. e h (name of person acknow•led—ging); ' -__._...... / Jc,s Signature of ivotary Public - State of Florida) Print:, Type, or Stamp Commissioned Natne of Notary Public) Personally Known OR Produced identification W_..___.._._., E,, cifto!ary r tli 51ate ,r r `TypeofIdentificationProducedEarl [Ion ald Naa,typ Expires02,11112027 .i 0 Page 4594 of 7162 Copier C014tti11,y Administrallo Services Department r6i:lirpntF:-'^Y St;,`VIC:P,S C3?bi5 m FORM 10- VENDOR Dt;csLARA' trt*; STAUMENT BOARD OF COUNTY COMMISSIONERS Collier County Government Complex Naples, Florida 34112 Dear Commissioners: T'he Undersigned, as Vendor declares that this response is made without connection or arrangement with any other person and this proposal is in every respect fair and made in good faith. without collusion or fraud. The Vendor hereby declares the instructions, purchase order terms and conditions, requirements, and specifications/scope of work of this solicitation have been fully examined and accepted. The Vendor agrees. if this solicitation submittal is accepted, to execute a Collier County document for the purpose of establishing a formal contractual relationship between the firm and Collier County, for the performance of all requirements to which the solicitation pertains. The Vendor states that the submitted is based upon the documents listed by the above referenced Solicitation, Further, the vendor agrees that if awarded a contract for these goods and/or services, the vendor will not he eligible to compete., submit a proposal, be awarded, or perform as a sub - vendor for any future associated with work that is a result of this awarded contract. IN WITNESS WHEREOF. WE have hereunto sub ribgd our names on this 4th day of June 20..20in the County of .. LCe in the State of ort a Finn's Legal Mitchell & Stark Construction Company, Inc. Name: Address: 6001 Shirley Street City. State, Zip Naples. Fl. 34109 Code: Florida 845897 Certificate of Authority Document Number 35-0964820 Federal Tax Identification Number CCR ti or CAGE Code Only if Grant Funded 239-597-2165 Telephone: Email: mwesthafer(r%mitchellstark.coni Signature by: Typed and written) Michael P. Westhafer. Vice President Title: 0 Page 4595 of 7162 send payments to: required if(ifferent from above) Contact name: Title: Address: Chi State, All I'elephunc: Additional Cmitact Information Company name used as payee LniAL Office ser% icing (.'oilier County to place orders required if different Aum above! InWo name: I BE Address: its. State. All Telephone: F. MA I: Brian Penner Secolldar Contact for this Solicitation: E::nmil: bpennerivnlitchellsiark.con) Phone: 29.547-2IGs 0 Page 4596 of 7162 Co ier comnty Adnw%trative services Departmenl FORM II-IMN11CRATION AFF'IDAVITCERTIFICATION This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with formal solicitation submittals. Further, Vendors are required to be enrolled in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Vendor's bid. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company which will be produced at the time of the submission of the Vendor's bid or within five (5) day of the County's Notice of Recommend Award, FAILURE TO EXECUTE THIS AFFIDAVIT" CERTIFICATION AND SUBMIT WITH VENDOR'S PROPOSAIJBID MA1' DEEM THE VENDOR NON -RESPONSIVE, Collier County will not intentionally award County contracts to any Vendor who knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 U.S.C:°. Section 1324 a(c) Section 274A(e) of the Immigration and Nationality .Act ("IN.A"). Collier County may consider the employment by arry Vendor of unauthorized aliens a violation of Section 274A (e) of the iNA. Such Violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be grounds for unilateral termination of the contract by C,'olher County. Vendor attests that they are fully compliant with all applicable immigration laws (specifically to the 1986 Immigration Act and subsequent Amendment(s)) and agrees to comply with the provisions of the Memorandum of Understanding with F-Verify and to provide proof of enrollment in The Employment. Eligibility Verification System (E-Verii'N operated by the Department of Homeland Security in partnership with the Social Security .Administration at the time ol'submission of the Vendor's bid. Mitchell & Stark Construction Company. Inc. r---- pany Marne Signature Michael P. Westhafer, Vice President Print Name and Title State of Florida County of ..........,ce The foregoing instrument was acknowledged before me by means of d physical presence or 0 online notarization, this _4th day of June (month), 2020 (year), by l4Tichael P, Westhafer ramie of person acknowledging). ti._... _ .. Signature of Notary Public - State of Florida) Print, Type, or Stamp Commissioned Name of Notary Public) Personally Known OR Produced Identification Type of Identification Produced r: Earl Done jid rt ias p My COMM:W091 CG 184, 20 f k'Dire5 02//112022. 0 Page 4597 of 7162 FORM 12 - BIDDERS CHECKLIST 7771 IMPORJ'ANT: Please read carefully, sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: I , The Bid has been signed. — 2, The Bid prices offered have been reviewed. 3. The price extensions and totals have been checked. 4. Bid Schedule has been completed and attached. —` 5, Any required drawings, descriptive literature, etc, have been included, G. Any delivery information required is included. -` 7. The following on-line standard documents have been reviewed and accepted in BidSync: a. Construction bid instructions forrn b. Construction services agreement --' c. Purchase order terms and conditions 8. All of the following bid forms have been completed and signed: a. Bid Form (Form 1) -— b. Contractors Key Personnel (Form 2) c. Material Manuiacturers, (Form 3) -' d. List of Major Subcontractors (Form 4) e. Statement of Experience (Form 5) f. french Safety Act (Form 6) g. Bid Bond Form (Form 7) ' h, Insurance and Bonding Requirements (Form 8) i. Conflict of Interest Affidavit (Form 9) " j. Vendor Declaration Statement (Form 10) k. Immigration Law Affidavit Certification (Form I I) MUST he signed and attached with your submittal or you MAN' be DEEMED NON -RESPONSIVE 1, Signed Grants Provisions and Assurances Package in its entirely, if applicable, are executed and should be included with your submittal. All forms must be executed, or you MAI" be DEEMED NON -RESPONSIVE ---' 9, Copies of required information have been attached a. Business tax Receipt (Collier County Businesses Only) b, Company's E-Verify profile paCge or memorandum of understanding c. Certificate of Authority to Conduct Business in State of Florida (sunbiz.org) d. Any required professional licenses , valid and current (myfloridalicensc.com ic: General Contractors license, Underground Utility and Excavation, Builders, Trade Contractors, etc.. as applicable, requested and -'or required.) 10, If required, the amount of Bid bond has been checked, and the Bid bond or cashier's check has been submitted. 11, Any addenda have been signed and acknowledgement form attached and included, or you MAI' be DEEMED NON -RESPONSIVE. 12. The Bid will be uploaded in time to be received no later than the specified openirt1 date and time, otherwise the Bid cannot be considered. 0 Page 4598 of 7162 4 per. C tc3i' a. r Q z to cc z J w w a U) co m t% r o- zzq- ww im Lu U- hirj LL o CL cn E N zh u N uxxw 46 40UJ V J CD At u ((( JJJ ]] E n 1U CL W 15 LU U ;ice tj IR t- Jf LU > x; 'A $ 00 N Q rx Q o Ul) U) v $ a ew y O J N U lJJ uvruji Q 06 6 tti W u c i3Lcn< Page 4599 of 7162 E-, e Company ID Number: 99962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (Of IS) and the Mitchell & Stark Construction Co , Inc (Employer) The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E,Verify, F Verify is a pirogram that electronically confirms an employee's eligibility to work in the United Stater, after completion of Form 1-9, Employment Eligibility Verification (Form 1-9) This Memorandum of Understandinq ; MOIJ) explains certain features of the E -Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA) and DHS Authority for the F,Venty program is found in Title IV, Subtitle A. of the Illegal immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Put) L 104-208, 110 Stat 3009, as amended (8 J S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18 "Employment Eligibility Verification' and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal contractor) to use F-Verify to verify the employment eligibility of cetlain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system a Notice of E-Verily Participation b Notice of Right to Work 2 The Employer agrees to provide to the SSA and DHS the names, titles. addresses, arid telephone numbers of the Employer representatives lobe contacted about E -Verify The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information Change$ 3 The Employer agrees to grant E-Verify access only to current employees who need E -Verify access Employers rtiust promptly terminate an employee's F -Verify access it the employer is separated from the company or no longer needs access to E -Verify PA'Jt 101 0 Page 4600 of 7162 Company ID Number: _499r1 4 The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual, 5 The Employer agrees that any Employer Representative who will create E -Verify cases will complete the E -Verify Tutorial before that individual creates any cases a, The Employer agrees that at] Employer representatives will take the refresher tutorlaIS w tieM prompted by E-Verify in order to continue using E-Verity Failure to Complete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify 6 T he Employer agrees to comply with current Form 1-9 procedures. with two exceptions a It an employee presents a 'L ist 8' identity document the Employer agrees to only accept 'List E" documents that contain a photo. (List 8 documents identified in 8 C.F R § 274a 2(b)(1)(B)) car) be presented during the Form 1-9 process to establish identity,) It an employee objects to the photo requirement for religious reasons. the Employer should contact E-Verify at 888-464-4216 b II an employee presents a CHS Form 1-551 {Permanent Resident Card), Farm 1-766 rriployment Authorization Document). or U S Passport or Passport Card it) complete Form 1- 9 the Employer agrees to make a photocopy of IhP document and to retain the photocopy with the employee s Form 1.9 1 he Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest DHS may in the future deslqriate, other documents that activate (tie photo screening tool Note Subject only to the exceptions noted previously in this paragraph employees Mill retain the right to present any List A or List 8 and List C. document(s) to complete the Form 1-9 7 The Employer agrees to record The case verification number on the employee's Form 1-9 or to print the screen containing the, ease verification number and attach it to the employee's Form 1-9 8 The Employer agrees that. although it participates in E-Venfy, the Employer has a responsibility to complete, retain, and make available for inspection Fonts 1.9 that relate to its employees, or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 2746 of the INA with respect to Form 1-9 procedures a The following modified requirements are the only exceptions to an FmpIDyef s obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the IN& (1) List B identity documents must have photos, as described in paragraph 6 above: (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E -Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(a)(1)(A) of the immigration and Nationality Act (INA) with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmahon for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and ' 51,100 for each failure to notify DHS of continued employment following a final nonconfirmation; (4) If the Employer continues to employ an employee after receiving a final nonconfornalion, then the Employer is subject to a rebuttable presumption that it has knowingly PV,, ? M ` C Ve,Of MOu I'Ll, Hnplk,yfts, Reosioi Daft. 06,01,13 0 Page 4601 of 7162 E-Verify......z Company ID Number: 9W2 employed an unauthorized alien in violation of section 274A(a)(1)(A), and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verity b DHS reserves the right to conduct Form 1,9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verify 9 The Employer is strictly prohibited from creating an E -Verify case before the employee has been hired, meaning that a firm otter of employment was extended and accepted and Form 1.9 was completed The Employer agrees to create an E -Verify case for new employees within three Employer business days after each employee has been hired (after bolt) Sections 1 and 2 of For") 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the F-Verify User Manual If E-Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting in good faith, to make inquiries during the period of unavailability 10 The Employer agrees not louse E -Verify for preemployment screening of job applicants: in support of any unlawful employment practice, or for any other use that this MOU cir the E-Verity Use, Manual does not authorize 11 The Employer must use E-Venly for air new employees 1 fie Employer will not verity selectively and will not verify employees hired before the effective date of this MOU Employers who are Federal contractors may quality for exceptions to this requirement as described in Article li,B of this MOU 12 The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employees F -Verity case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding and not take adverse action against employees if they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmalion based upon a photo mismatch, the Employer must take additional steps see Article III B below) to contact MiS with infoirmalion necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or OHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C F,R § 274a, 1(l)) that the ernployele, is not work authorized The Employer understands that an initial inability of the SSA or OHS automated verification system to verity work authorization, a tentative nonconfirmation, a case in continuance indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized In any of such cases, the employee must he provided a full and fair opportunity to contest the finding: and of he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status FaV 3 DI 17 F,vtnf f.AD,,# to, frnployt,s ! Pey,vo+ Wie 0 Page 4602 of 7162 Company ID Number; 9M2 including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or OHS has been completed and a final nonconfirmation has been issued. If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers of employees with questions about a final nonconfirmation may call E-Verify at 1-888A64- 4218 (customer service) or 1.88&-897-7781 (worker hotline) 14 The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 274B of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by commintrig discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E-Verify except as provided in part D Wow, or discharging or refusing to hire employees because they appear or sound foreign- or have received tentative nonconfirmattons The Employer further understands that any violation of the, immigration -related unfair employment practices provisions in section 274E of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title Vil could subject the Employer to back pay awards, compensatory and punitive damages Violations of either section 2746 of the INA or Title V11 may also lead to the termination of its participation in F-Verify If the Employer has any questions relating to the anti -discrimination provision it should contact OSC at 1.800-255-8155 or 1-800.237-2515 JDD) 15 The Employer agrees that it will use the information it receives front E-Verify only to confirm the employment eligibility of employees as authorized by this MIOU The Employer agrees that 1 will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality. including ensuring that it is not disseminated to any person other than employees of the Employer who are authori2ed to perform the Employer's responsibilities under this MOU except for such dissemination As may be authorized in advance by SSA or OHS for legitimate purposes 16 The Employer agrees to notify OHS immedratefyin the event of a breach of personal information Breaches are defined as loss of control or unauthorized access to E-Verify personal data All su"cled or confirmed breaches should be reported by calling 1-888-464.4218 or via email at E-VerifyPdhs.qoy Please use "Privacy Incident - Password' in the subject line of your email when sending a breach report to E-Vertty 17 The Employer acknowledges that the information it receives from SSA is governed by I fie Privacy Act J5 U,S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)) Any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties 18 The Employer agrees to cooperate with OHS and SSA in their compliance monitoring and evaluation of F-Verify, which includes permitting OHS SSA. their contractors and other agent, upon Page 4 CY 9 F Vt"'N MOU to, Revis,on Ua!t W01113 ICAOCAO Page 4603 of 7162 Campany to Numbev 9VA2 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-VOfy, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Venty. 19 The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media The Employer shall not describe its services as federally -approved, federally -certified, or federally -recognized, or use language with a similar intent on its website of other materials provided to the public Entering into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effect is false 20 The Employer shall not state in its website of other public documents that any language used therein has been provided or approved by OHS. USCIS or the Verification Division, without first obtaining the prior written consent of DHS 21 The Employer agrees that E-Verify trademarks and logos maybe used only under license by DHS/USCIS (see M-72§ Web terms of such license, may notL ... J) and, other than pursuant to the specific be used in any manner that might imply that the Employer's services products, websites, or publications are sponsored byendorsed by, licensed by, or affiliated with DHS, USCIS. or E -Verify 22 The Employer understands that it it uses E Verify procedures for any purpose other tnan, as authorized by this MOU. the Employer may be subject to appropriate legal action and termination of its participation in E-Verify, according to this MOU B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1 It the Employer is a Federal contractor with the FAR E-Venty clause subject to the empi0yrneill verification terms in Subpart 22 18 of the FAR, A wili become farnifiaf with and comply with the most current version of the E-Venfy User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands, that if it is a Federal contractor subject to the employment verification leans in Subpart 22.18 of the FAR it must verity the employment eligibility of any 'employee assigned to the contract" (as defined in FAR 22 1801) Once an employee has been verified through E-Verily by the Employer the Employer may not create a second case for the employee through E-Verity. a An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verity employment eligibility of new hires usingE- Verify The Employer must verity those employees who are working in the United States, whether or not they are assigned to the contract Once the Employer begins verifying new hires such verification of new hires must be initiated within three business days after the hire date Once enrolled in E-Verify as a Federal contractor, the Employer must begin verification Of tfnpI0yeeS assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee' s assignment to the contract, whichever date is later Paqu t 0 , ? E VeOMOU to, Ery'krus I Care OCOIQ Page 4604 of 7162 Company 10 Number : 9-0%2 b. Employers enrolled in E-Verify as a Federal contractor tot 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility tot new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Employer must, within 90 days of enrollment, begin to use E-Verity to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract Such verification of new hires must be initiated within three, business days after the date of hire An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later c Federal contractors that are institutions of higher education (as defined at 20 U S C stale of local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986 Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employees assignment to the contract, whichever date is later d Upon enrollment. Employers who are Federal contractors may elect to verity employment eligibility of all existing employees working in the United States who were hired after November 6., 1986, instead of verifying only those employees assigned to A covered Federal contract Aftef enrollment, Employers must elect to verify existing staff following DNS procedures and begin E Verify verification of all existing employees within 180 days after the election e The Employer may use a previously completed Form 1.9 as the basis tot creating an L Verify case for an employee assigned to a contract as long as That Form 1-9 is complete (including the SSN) and complies with Article 11 A is it The employee's work authorization has not expired and iii. The Employer has reviewed the Form 1.9 informat-on either in person of in communications with the employee to ensure that the employee's Section 1, F orrn 1-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U.S. citizen) f The Employer shall complete a new Form 1.9 consistent wish Article 11 A 6 or krpdate the previous Form 1.9 to provide the necessary information if I The Employer cannot determine that Form 1-9 complies with Article If A.6. it The employee's basis tot work authorization as attested in Section 1 has expired of changed, or fit The Form 1-9 contains no SSN of is otherwise incomplete Note If Section 1 of Form 1.9 is otherwise valid and up-to-date and the form otherwise complies with Pj9t- tot I 7 f vtflfy PAW to, 1^01oyufE . Rev,sion Wit, 06,01;13 0 Page 4605 of 7162 Company ID Nurriber; 99%2 Article 11 C.5, but reflects documentation (such as a U,S. passport or Form 1-551) that expired after completing Form 14 the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article IIA5 subject to any additional or superseding instructions that may be provided on this subIecl in the E-Verily User Manual 9 The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU of to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that if it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract of subcontract, and the Employer consents to the release of information (elating to compliance with its verification responsibilities under this MOU to contracting officers of other officials authorized to review the Employer's compliance with Federal contracting requirements, C. RESPONSIBILITIES OF SSA I SSA agrees to allow DHS to compare data provided by the Employer against SSAs database SSA sends DHS confirmation that the data sent either matches of does not match the information in SSA s database 2 SSA agrees 10 safeguard the information the Employe( provides through E, Verity procedures SSA also agrees to limit access to such information. as is appropriate by law, to indIV4dual,, responsible for the verification of Social Security numbers of responsible for evaluation. of E -Verity or such other persons or entities who may be authorized by SSA as governed by the Privacy Act (5 U 5 C § 552a) the Social Security Act (42 LJI S.0 1306(a)), and SSA reclulations (20 CFR Parl 401) 3 SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry E-Verify provides the information to the Employer. 4 SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence If the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, it appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary In such cases. SSA will provide additional instructions to the employee If the employee does not visit SSA in the time allowed, E -Verify may provide a final nonconfirmation to the employer Note If an Employer experiences technical problems, of has a policy question, the employer should contact E.-Verify at 1-888-464-4216 O. RESPONSIBILITIES OF OHS 1 OHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct. to the extent authorized by this MOU a Automated verification checks on alien employees by electronic means, and Pwr, " o! I? I vtnfy Mou for trrptyer, I Revrsg)n Oalt 06:0113 0 Page 4606 of 7162 Company ID Number: 99962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DHS) and the Mitchell & Stark Construction Co , Inc (Employer) The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in F-Verify. F-Verify is a program that electronically confirms an employee's e69,bfI!Iy to work in the United States after completion of Form 1.9, Employment Eligibility Verification (Form 1-9) This Memorandum of Understanding (MOO) explains certain features of the E-Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA), and DHS Authority for tne I -Verity program is found in I site IV, Subtitle A. of the Illegal immigration Reform and Immigrant Responsibility Act at 1996 (IIRIRA), Put) L 104-208, 110 Stat 3009 as amended (6 U S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18 "Employment Efigiblilly Verification' and Executive Order 12989, as amended provide authority for Federa! contractors and subcontractors (Federal contractor) to use E-Verify to verify the employment eligibility of certain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER I The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system a Notice of E-Verify Participation b Notice of Right to Work 2 The Employer agrees to provide to the SSA and DHS the names, lilies, addresses. and telephone numbers of the Employer representatives to be contacted about E -Verify The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes 3. The Employer agrees to grant E-Verify access only to current employees who need E-Versify access Employers must promptly terminate an employee's E -Venty access if the employer is separated from the company or no longer needs access to E -Verify F'49# 10 17 [-Verity Wu to, Empkqt-f, I Re.,s*a [)ale 06?C v I 0 Page 4607 of 7162 1111.— V er"Ify— Company ID Numbvv 99962 4 The Employer agrees to become familiar with and comply with the most recent version of the E- Verify User Manual. 5. The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E -Verify Tutorial before that individual creates any Cases a The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E -Verity in order to continue using E -Verify Failure tocomplete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify 6 1 he Employer agrees to comply with current Form 1,9 procedures, with two exceptions a It an employee presents a *List 8' identity document, the Employer agrees to only accept "List S' documents that contain a photo. (List 8 documents identified in 8 C F R § 274a 2ftl)(B)) can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons, the Employer should contact E-Verify at 898- 464-421& b If an employee presents a DNS Form 1-551 (Permanent Ret.,ideni Card), Form 1-766 Employment Authorization Document), or U S Passport or Passport Card to complete Farm 1.9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employees Form 1-9, The Employes will use the photocopy to verify the photo and to assist OHS with its review of photo mismatches that employees contest DfiS may in the future designate other documents that activate the photo screening tool Note Subject only to the exceptions noted previously in this paragraph, employees still retain the rf(Jhl to present any List A or List 8 and List C. document(s) to complete the Form 1.9 7 The Employer agrees to record the case verification number on the employee's Form 1.9 or to print the screen containing the case verification number and attach it to the employee's Form 1-9 8 The Employer agrees that, although it participates in E-Verify, the Employer has a responsibility to Complete, retain, and make available for inspection Forms 1-9 that relate to its employees. or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 274E of the INA with respect 10 Form 1,9 procedures. a The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the antidiscrimination provision of the INA, (1) List 8 identify documents must have photos, as described in paragraph 6 above: (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the E mptoyer establishes a rebuttable presumption that it has not violated section 274A(ay 1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of that employee; 3) If the Employer receives a final nonconfirmation for an employee. but continues to employ that person, tie Employer must notify DNS and the Employer is subject to a civil money penalty between $550 and $ 1, 100 for each failure to notify OHS of continued employment following a final nonconfirmation, ( 4) If the Employer continues is employ an employee after receiving a final ncnconfirmabon, then the Employer is subject to a rebuttable presumption that it ha, knowingly f, agt ; of 17 F VtqifV JK)J fog Fjr.r.;0,*,S Rii,l%ion [)ate 06,,01,111 0 Page 4608 of 7162 E-Varify---- Company 10 Number , 99962 employed an unauthorized alien in violation of section 274Na)(1)(A), and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verity, b DNS reserves the right to conduct Form 1-9 compliance inspections as well as any other enforcement or compliance activity authorized by taw, including site visas, to ensure proper use of E-Verify, 9 The Employer is strictly prohibited from creating an E-Verity case before the employee has been hired, meaning that a form offer of employment was extended and accepted and Form 1-9 was completed The Employer agrees to create anE-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections I and 2 of Form 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the F-Verity User Manual If E -Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate, the Employer's attempting, in Good faith, to make inquiries during the period of unavailability 10 The Employer agrees not to use E-Verify for pre -employment screening of job applicants, in support of any unlawful employment practice or for any other use that this MOU or the E-Verify Use, Manual does not authorize 11 The Employer must use E -Verify for all new employees The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article ILB of thi,_s, MOU 12 The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations The Employer must promptly notify employees in prtvate of the finding and provide them with the notice and letter containing information specific to the employees E -Verify case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding, and not lake adverse action against employees if they choose to contest the finding• while their case is still pending Further, when employees contest a tentative nonconfirmalion based upon a photo mismatch, the Employer must take additional steps see Article III B below) to contact DNS with information necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DNS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C F R § 274a 1(l)) that the employee is not work authorized The Employer understands that an initial inability of the SSA or DHS automated verification system to verify work authorization, a tentative nonconfirmation, a case in continuance indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized In any of such cases, the employee must be provided a lull and fair opportunity to contest the finding. and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status PaOf icy! 17 F,V*14 MO•O to, Imotovert " Rews,on Wit WUII13 0 Page 4609 of 7162 CornPany IU Nunibei 49%2 including denying, reducing, or extending work hours, delaying of preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218 (customer service) or 1.888-897-7781 (worker hotline) 14 The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 2748 of the INA as applicable by not discriminating unlawfully against any Individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E-Venty except as provided in part D below, or discharging or refusing to hire employees because they appeal of sound foreign" or have received tentative nonconfirmalions The Employer further understands that any violation of the immigration -related unfair employment Practices Provisions In section 2748 of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject the Employer to back pay awards compensatory and punitive damages Violations of either section 2748 of the INA or Title VII may also lead to the termination of its Participation in E-Venfy If the Employer has any questions relating to the anti -discrimination provision, it should contact OSC at 1-800.255-8155 or 1.800-237-2515 (TDD) 15 The Fmployer agrees that it will use tree information it receives from E-Verify only to confirm the, employment eligibility of employees as authorized by this MOU The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who rare authorized to perform the Employer's responsibilities under this MOU, except for such dissemination as may be authorized in advance by SSA of DHS for legitimate purposes 16 The Employer agrees to notify DHS immediately in the event of a breach of personal information breaches are defined as loss of control or unauthorized access to EVerity personal data. All suspected or confirmed breaches should be reported by calling 1-888,464-4218 or via email at E- Yerify0dh§,..qq yPlease use Privacy incident - Password' in the subject line of your email when sending a breach report to E -Verity 17 The Employer acknowledges that the Information it receives from SSA is governed by the Privacy Act ( 5 U.S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)). Any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOO may be subject to criminal penalties 18 The Employer agrees to cooperate with OHS and SSA in their compliance monitoring and evaluation of E-Verify. which includes permitting OHS SSA, their contractors and other agents, upon Wage A 01 11 (-vwls Mfor CMP1*YVS i ke.t5mn Gait W01103 0 Page 4610 of 7162 Compony ID Nvmbef99%2 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19 The Employer shall not make any false or unauthorized claims or references about its participation in E-Venty on Its website, in advertising materials, or other media The Employer shall not describe 4s service.- as federally -approved, federally -certified, or federally- recognized, or use language with a similar intent on its website or other materials provided to the public Entering into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effecl is false 20 The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS 21 The Employer agrees that E-Verify trademarks and logos may be used only tinder license by DHS/ USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services, products, websites, of p, iblications are sponsored by, endorsed by, licensed by: or affiliated with DHS, USCIS or E--Verify 22 The Employer understands that it it uses E Verify procedures lot any purpose other than as authorized by this MOU. the Employer may be subject to appropriate legal action and termination of Its participation in E -Venty according to this MOU B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1 If the Employer is a Federal contractor with the FAR F-Venty clause subject to the employment verification terms in Subpart 22 18 of the FAR, I wilbecome familiar with and comply with the most current version of the F.-Venty User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must verity the employment eligibility of any 'employee assigned to the contract' (as defined in FAR 22 1801) Once an employee has been verified through E.-Verify by the Employer. the Employer may not create a second case for the employee through E-Verify a An Employer that is not enrolled in E-Verity as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verify employment eligibility of new hires using E- Verify The Employer must verify those employees who are working in the United States, whelhe( or not they are assigned to the contract Once the Employer begins verifying new hires, such verification of new hires must be initiated within three business days slier the hire date Once enrolled in E -Verify as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment of within 30 days of an employee's assignment to the contract, whichever date is later Page b 01 1: v(-.0) MOU IV Efr.plcyers I Hey'von Wit! 06,01,13 0 Page 4611 of 7162 Am=* M M tiveri f Company 10 Numbec 9W2 b Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Emptoyet must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract Such verification of new hires must be initiated within three business days after the dale of hire An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the cuntract, whichever is later. c Federal contractors that are institutions of higher education (as defined at 20 U S C. 1001 (a)), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however elect to verify all new hires. and/or all existing employees hired after November 6, 198433 Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee s assignment to the contract, whichever date is later d Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United States who were hired after November 6, 1966, instead of verifying only those employees assigned to a covered Federal contract After enrollment, Employers must elect to verify existing staff following DNS procedures and begin C -Verify verification of all existing employees within 180 days after the election. c The Employer may use a previously completed Form 1-9 as the basis tot cresting an, E-Verify case tot an employee assigned to a contract as long as. That Form 1-9 is complete (including the SSN) and complies, with Article ILA 6 ii The employees work authorization has not expired and iii. The Employer has reviewed the Form 1-9 information either in per sari or in communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U S citizen) I The Employer shall complete a new Form 1-9 consistent with Article 11 A 6, or update the previous Form 1.9 to provide the necessary information it 1 The Employer cannot determine that Form 1-9 complies with Article HA 6. ii The employee's basis for work authorization as attested in Section 1 has expired or changed.or in The Form 1.9 contains no SSN or is otherwise incomplete Note If Section I of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies w1th Paget 0 1;( Vtnfy PAO-1 V F. nDioytr.- Re vimvi Wit, 0-5101;13 0 Page 4612 of 7162 Company ID Number, 90-%-2 Article It C.5, but reflects documentation (such as a U.S passport or Form 1-551) that expired after completing Form 1.9, the Employer shah not require the production of additional documentation, or use the photo screening tool described in Article II.A.5. subject to any additional or superseding instructions that may be provided on this subject in the E•Verify User Manual g The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that it it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontractand the Employer consents to the felease of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements C, RESPONSIBILITIES Of SSA I BSA agrees to allow OHS to compare data provided by the Employer against BSA's database SSA sends OHS confirmation that the data sent either matches of does not match the information in SSA's database, 2 SSA agrees to safeguard the information the Employer provides through E Verity Procedures SSA also agrees to iimd access to such information, as is appropriate by law, to individuals responsible for the verif tcation of Social Security numbers of responsible for evaluation of E -Verify or such other persons or entities Who may be authorized by BSA as govemed by the Privacy Act (5 U S C § 552a), the Social Security Act (42 U S C 13%(a)), and BSA regulations (20 CFR Part 401) 3 BSA agrees to provide case results from its database within three Federal Government workdays of the initial inquiry E -Verify provides the information to the Employer 4 BSA agrees to update BSA records as necessary if the employee who contests the BSA tentative nonconfirmation visits an BSA field office and provides the required evidence If the employee visits an BSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, if appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary In such cases BSA will provide additional instructions to the employee If the employee does not visit BSA in the time allowed, E Nerify may provide a final nonconfirmation to the employer. Note: If an Employer experiences technical problems, of has a policy question, the employer shouid contact E-Verify at 1.888-464-4218 D. RESPONSIBILITIES OF OHS I DNS agrees to provide the Employer with selected data from DNS databases to enable the Employer to conduct, to the extent authorized by this MOU a Automated verification checks on alien employees by electronic rneans, and page 7 04 1) k veor kfou (t)t tmpfoyefs I RfV,W.rn Date 06,1,Wl3 00 Page 4613 of 7162 E Ve r i fy__ company ID Number: 99962 b. Photo verification checks (when available) on employees 2 DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. OHS agrees to provide the Employer names, titles, addresses, and telephone numbers of OHS representatives to be contacted during the E-Venty process 3 OHS agrees to provide to the Employer with access to E-Verify training materials as well as an E-Verify User Manuel that contain instructions on E-Verify policies procedures, and requirements for both SSA and OHS, including restrictions on the use of E-Verily 4 DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manuel Even without changes 10 E-Verify OHS reserves the right to require employers to take mandatory refresher tutorials 5 DHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E -Venfy. OHS also agrees to provide to the Employer anti -discrimination notices issued by the Office of Special Counsel for immigration -Related Unfair Employment Practices (OSC), Civil Rights Division. U S Deparimerill of Justice 6 DHS agrees to issue each of the Employer s E-Verify users a unique user identification number and password that permits them to tog in to E Verify 7 DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E-Verify, or to such other persns or entities as may be authorized by applicable law Information will be used only to verify the accuracy of Social Security numbers and employment eligibility, to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements. 8 DHS agrees to provide a means of automated verification that provides (in conjunction w4h SSA verification procedures) confirmation or tentative nonconfirmalion of employees' employment eligibility within three Federal Government work days of the initial inquiry 9, DHS agrees to provide a means of secondary verification (including updating OHS records) for employees who contest OHS tentative nonconfirmations, and photo mismatch tentative nonconfirmations This provides final confirmation or nonconfirmation of the employees* employment eligibility within 10 Federal Government work days of the date of referral to DHS. unless DHS determines that more than 10 days may be necessary In such cases. DHS will provide additional verification instructions ARTICLE III REFERRAL_ OF INDIVIEWALS TO SSA AND OHS A. REFERRAL TO SSA 1 If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the ernployee's E-Verify Page 0 D1 17 t VefVy MOU to, Fmt)i0iW, Is.. Rev -go, 09it D61(31,13 Page 4614 of 7162 Company ID Number: 99962 b Photo verification checks (when available) on employees, 2 OHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verity OHS agrees to provide the Employer names, titles, addresses, and telephone numbers of OHS representatives to be contacted during the E-Verify process 3. OHS agrees to provide to the Employer with access to E-Verify training materials as well as an E -Verify User Manual that contain instructions on E-Verify policies, procedures, and requirements for both SSA and DHS, including restrictions on the use of E-Verify. 4 OHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manual Even without changes to E .,Verify, OHS reserves the right to require employers to take mandatory refresher tutorials 5 OHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E -Venfy DHS also agrees to provide to the Employer anti -discrimination notices issued by the Office of Special Counsel for Immigration -Related Unfair Employment Practices (OSC), Civil Rights Division, 0 S. Department of Justice 6 DHS agrees to issue each of the Employer's E -Verify users a unique user identification number art,) password that permits them to log in to E-Verify 7 DHS agrees to safeguard the information the Employer provides, and to Ilmd access to such information to individuals responsible for the verification process for evaluation of E-Verify, or to such other persons or entities as may be authorized by applicable law Information will be used only to verity the accuracy of Social Security numbers and employment eligibility. to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements 8 OHS agrees to provide a means of automated verification that provides (in conjunction with SSA verdicalion procedures) confirmation or tentative nonconfirmalion of employees' employment eligibility within three Federal Government work days of the initial inquiry 9 OHS agrees to provide a means of secondary verification (including updating OHS records) for employees who contest OHS tentative nonconfirmations and photo mismatch tentative nonconfirmations This provides final confirmation of nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS, unless DHS determines that more than 10 days may be necessary In such Gases, DHS will provide additional verification instructions ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA I If the Employer receives a tentative nrinconfinnation issued by SSA. the Employer must print the rot" as directed by E -Verify The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the ernployee's E-Verify Page 9 01 17 E Venly MOU fe± Ffn0foyers I pe.jsolt Date. W0103 0 Page 4615 of 7162 A1,111:1,"I'll611rif Y Company to Number 99962 case The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation Only the employee may determine whether he or she will contest the tentative nonconfirmation 3 After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed by E-Verify The Employer must record the case verification number, review the employee information submitted to E-Verify to identify any errors, and find out whether the employee contests thc, tentative nonconfirmation The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again it this review indicates a need to do so 4 1 he Employer will instruct the employee to visit an SSA office within eight F elde rat Government wort; days SSA will electronically transmit the result of the referia± to the Employer within 10 Fecleta( Government worm days of the referral unless it determines that more than 10 days is necessary 5 While waiting for case results the Employer agrees to Check the E -Verify system regularly for case updates 6 The Employer agrees not to ask the employee to obtain a printout from the Social Security Administration number database (the Numident) or other written verificalion of the SSN from the SSA B. REFERRAL TO DHS I If the Employer receives a tentative nonconfirmation issued by OHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E -Verify case The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the, tentative nonconfirmation Only the employee may determine whether he or she will contest the tentative nonconfirmation 3 The Employer agrees to refer individuals to OHS only when the employee chooses to contest a tentative nonconfirmation 4 If the employee contests a tentative nonconfirmation issued by OHS, the Employer will instruct the P40f 401 11 F Vtnfy MOU 6 Emrloyr" I R,-4,von Oar* 06ro 1, 13 a Page 4616 of 7162 erify__zIr Company 10 Numbec 99962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DfIS) and the Mitchell & Stark Construction Co, Inc (Employer) The purpose of This agreement is to set forth terms and conditions which the Employer will follow while participating in F-Verify F Verify is a program that electronically confirms an employee's eligibility to work in the United States after completion of Form 1-9, Employment Eligibility Verification (Form 1-9) This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA), and DNS Authority for the IF -Verity program is found in Title IV, Subtitle A. of the Illegal Immigration Reform and Immigrant Responsibility A0 of 1996 (IIRIRA). Pub L 104.208, 110 Stat 3009. as amended (8 U S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18 'Employment Eligibility Verification" and Executive Order 12989. as amended provide authority for Federal conlraclors and subcontractors (Federal contractor) to use E-Verily to verify the employment eligibility of certain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER 1 The Employer agrees to display the following notices supplied Uy DNS in a prominent place that is clearly visible to prospective employees and all employees who are Ic be verified through the system a Notice of E-Verily Participation b Notice of Right to Work 2 The Employer agrees to provide to the SSA and DNS the names, titles. addresses, and telephone numbers of the Employer representatives to be contacted about E -Verity The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes 3 The E mptDyer agrees to grant E -Verify access only to current employees who need E-Verify access Employers must promptly terminate an employee',, E-Venfy access if the employer is separated from the company or no longer needs access to E -Verify Flav , 0 17 1, "Ve"i" "Ou roc Umpiovos I Rev;soon 08tr WO 1; 1A, a Page 4617 of 7162 mom i-Verif y...... Company ID Number. 99%2 4 The Employer agrees to become familiar with and comply wilh the most recent version of the E-Verify User Manuel. 5 The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases a The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E-Verify in order to continue using E-Verify. Failure to complete a refresher lulonal will prevent the Employer Representative from continued use of E-Verity 6 The Employer agrees to comply with current Form 1.9 procedures, with two exceptions a 11 an employee presents a 'List 6* identity document, the Employer agrees to only accept "List E' documents that contain a photo, (List 6 documents identified in 6 C,F R § 274a 2( b)(1)(8)) can be presented during the Form 1-9 process to establish identity.) If an employee objects In the photo requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218 b If an employee presents a DHS Form 1.551 (Permanent Resident Card). Form 1-766 Employment Authorization Document), or U S Passport or Passport Card to complete Form 1-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employees Form 1-9, The Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest DHS may in the future designate other documents that activate the photo screening tool Note Subject only to the exceptions noted previously in this paragraph, employees still retain the right to present any List A, or List 8 and List C. document(s) to complete the Form 1-9 7 The Employer agrees to record the case verification number on the employee's Form 1-9or to print the screen containing the case verification number and attach 0 to the employee's Form 1,9 8 The Employer agrees that, although it participates in E-Verify, the Employer ties a responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from other requirements of applicable regulations or laws, including The obligation to comply with the antidiscrimination requirements of section 2746 of the INA with respect to Form 1-9 procedures a The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the INA. (1) List 6 identity documents must have photos, as described in paragraph 6 above-, (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(ay, 1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of that employee-, (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penally between $550 and S 1,100 for each failure to notify DHS of continued employment following a final nonconfirmation: (4) It the Employer continues to employ an employee after receiving a final nonconfirmalion, then the Employer is subject to a rebuttable presumption that it has knowingly i"o9t r of I r I voif) MOa knF f-rrp"ers ke-wo- Date 06 01, 1) 0 Page 4618 of 7162 Company 10 Numbev 49%2 employed an unauthorized alien in violation of section 270(a)(1)(A), and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b OHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visilS, to ensure proper use of E-Verity. 9 The Employer is strictly prohibited from creating an E-Veyify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed The Employer agrees to aeate an E -Verity case for new employees within three Employer business days after each employee has been hired {after both Sections I and 2 of Form 1-9 have beer) completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual It F-Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting, in good faith. to make inquiries during the period of unavailability 10 The Employer agrees not to use E-Verity for pre -employment screening of job applicants, in support of any unlawful employment practice, or for any other use that this MOV of the E -Verify Use, Manual does not authorize 11 The Employer must use E-Venly for all new employees The Employer will not verity selectively and will not verily employees hired before the effective dale of this MOU Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article 11.8 of thiw MOU 12, The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSAThe Employer must allow employees to contest the finding, and not lake adverse action against employees erintosif they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmation based upon a photo mismatch, the Employer must lake additional steps see Article III B below) to contact OHS with information necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee' s perceived employment eligibility status while SSA or OHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a, 1(l)) that the employee, is not work authorized The Employer understands that an initial inability of the SSA or OHS automated verification system to verity work authorization, a tentative nonconfirmation. a case in continuance indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is riot work authorized In any of such cases, the employee must be provided a full and fair opportunity to contest the finding and it he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status Papf 3 (if 17 F-vWifi P,10,J lo, PMployets I Rev"'On Date (It"Wila 0 Page 4619 of 7162 17 Ve r"Ify a Tr -, Company ID Nutirtber. 99962 including denying, reducing, or extending work hours, delaying of preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or OHS has been completed and a final nonconfirmation has been issued It the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218 (customer service) or 1-888- 897-7781 (worker hotline) 14 The Employer agrees to comply with Title Vil of the Civil Rights Act of 1964 and section 2748 of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or tier national origin or citizenship status, of by committing discriminatory documentary practices The Employer understands that such illegal practices can include selective verification or use of E-Verity except as provided in part D below, or discharging or refusing to hire employees because they appear or sound foreign' or have received tentative nonconfirimations 'The Employer further understands that any violation of the immigration related unfair employment practices provisions in section 274E of the INA could subject the Employer to civil penalties, back pay a -wards, and other sanctions, and violations of Title Vil could subject the Employer to back pay awards, compensatory and punitive damages Violations of either section 2.74B of the INA or Title V1 I may also lead to the termination of its participation in E-Venfy, If the Employer has any questions (elating to the arilt-dissemination provision, it should contact CISC at 1.800-255-8155 or 1-800.237-2515 (TDD) 15 The Employer agrees that it will use the information it receives from E-Verity only to confirm the employment eligibility of employees as authorized by this MOtl The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to project its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU. except for such dissemination as may be authorized in advance by SSA or OHS for legitimate purposes 16 The Employe( agrees to notify DHS immediately in the event of a breach of personal informaltur) Breaches are defined as loss of control or unauthorized access to E Verify personal data All suspected or confirmed breaches should be reported by calling 1,888-464-4218 or via email at E-Vefify0dh _q_qy Please use "Privacy Incident - Password' in the subject line of your email Mien sending a breach report to E -Verity 17 The Employer acknowledges that the information it receives from SSA is governed by the Privacy Act (5 U.S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)) Any person who obtains this information under false pretenses of uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties 18 Ihe Employer agrees to cooperate with OHS and SSA in their compliance monitoring and evaluation of E-Verity, which includes permitting DHS SSA, their contractors and other agents, upon Page 4 01 0 F ver'N Mold fol EmAlogers . pews;m Cate 06,01113 0 Page 4620 of 7162 Company 10 Numbef. 99%2 reasonable notice, to review Forms 1.9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19 The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on Its website, in advertising materials, or other media The Employer shall not describe its services as federally -approved, federally -certified, or federally- recognized, or use language with a similar intent on its websile or other materials provided to the public Entering Into this MOU does not mean that F-Venty endorses or authorizes your E-Venly, services and any claim to that effect is false. 20 The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS 21 The Employer agrees that E-Verify trademariks, and logos may be used only tinder license by DHS/USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may nr.,l be used in any manner that might imply that the Employer's services products, websiles, of publications are sponsored by, endorsed by, licensed by, or affiliated with DHS. USCIS or L,Vefify 22 The Employer understands that if it uses E Verify procedures for any purpose other than as authorized by this MOU, the Employer may be subject to appropriate legal action and termination of its participation in E,Verify according to this MOU 6, RESPONSIBILITIES OF FEDERAL CONTRACTORS I It the Employer is a Federal contractor with the FARE -Venty clause subject 10 the employment verification terms in Subpart 22 18 of the FAR, it will become familiar with and comply with the most current version of the E. Verity User Manual for Federal Contractors as well as the E-Verity Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must venly the employment eligibility of any 'employee assigned to the contract' (as defined in FAR 22 1801) Once an employee has been verified through E-Verify by the Employer, the Employer may not create a second case for the employee through E-Venly. a An Employer that is not enrolled in E-Verity as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award arid, within 90 days of enrollment, begin to verily employment eligibility of new hires using E-Verify The Employer must verify those employees who are working in the United States, whether or not they are assigned to the contract. Once the Employer begins verifying new hires such verification of new hires must be initiated within three business days after the hire date Once enrolled in E-Verily as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the dale of enrollment or Within 30 days of an employee's assignment to the contract, whichever date is later Page ol I? F Ve,,Ft ?J010 lo, Errplcyefs J Rcv-sw, 'Dair 06,'01113 a Page 4621 of 7162 E Ver i fy____ Company ID Number: 99%2 b Employers enrolled in E-Verify as a Federal contractor for 90 days of more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire It the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Employer must, within 90 clays of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United Slates, whether or not assigned to the contract Such verification of new hires must be initialed within three business days after the date of hire. An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later c Federal contractors that are institutions of higher education (as defined at 20 U S, C. V)() I state or local governments, govemments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into witty a Federal agency under a performance bond may choose to only verity new and existing employees assigned to the Federal contract Such Federal contractors may, however, elect to verity all new hires, and/or all existing employees hired after November 6, 1986 Employers in this category must begin verification of ernployee,, assigned to the contract within 90 calendar days after the dale of enrollment or within 30 days of an ernployee's, assignment to the contract, whichever date is later c Upon enrollment. Employers who are Federal contractors may elect to verity employment eligibility of all existing employees working in the United States who were hired after November 6, 1986, instead of verifying only those employees assigned to a covered Federal contract After enrollment Employers must elect to verity existing staff following DHS procedures and begin E,Verily verification of all existing employees within 180 days after the election e The Employer may use a previously completed Form 1,9 as the basis for creating an E-Verify case for an employee assigned to a contract as long as I That Form 1-9 is complete (including the SSN) and complies with Article I IA 6, if The employee's work authorization has not expired and iii The Employer has reviewed the Form 1.9 intormaton either in person of in Communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed (including, but riot limited to. a lawful permanent resident afieri, having become a naturalized U.S citizen) f The Employer shall complete a new Form 1-9 consistent with Article It. A 6 or update the previous Form 1-9 to provide the necessary information if I The Employer cannot determine that Form 1-9 complies with Article IVA 6. if The employee's basis for work authorization as attested in Section I has expired of changed of iij The Form 1.9 contains no SSN of is otherwise incomplele NIOR, If Section 1 of Form i.9 is otherwise valid and up-to-date and (tie forin otherwise complies with P49c (of I; F verify IN.),) fo, fmpi*W- tale o6,,ui,i-, 0 Page 4622 of 7162 Company ID Numbitr, 996*2 Article 11 C,5, but reflects documentation (such as a U.S passport or Form 1.551) that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article 11,A,5; subject to any additional of superseding instructions that may be provided on this subject in the E-Verity User Manual g The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that slit is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements C. RESPONSIBILITIES OF SSA I SSA agrees to allow OHS to compare data provided by the Employer against SSA s database SSA sends DHS confirmation that the data sent either matches of does not match the informalion in SSA S database 2 SSA agrees to safeguard the information the Employer provides through E-Verify Procedures SSA also agrees to limit access to such information, as is appropriate by law, to individuals responsible for the verification of Social Security numbers or responsible for evaluation of F -Verify or such other persons of entities who may be authorized by SSA as governed by the Privacy Act (5 U S C § 552a), the Social Security Act (42 U S C 1306(a)), and SSA regulations (20 CFR Part 401) 3 SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry E-Verity provides the information to the Employer 4 SSA agrees to update SSA records as necessary• if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence It the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, it appropriate, within the eight -day period unless SSA determines that more than eight days maybe necessary In such cases, SSA will provide additional instructions Ifithe employee If the employee does not visit SSA in the time allowed, U -Verify may provide a final nonconfirmation to the employer. Note, It an Employer experiences technical problems, or has a policy question, the employer should contact E-Verify at 1-888-464-42 18 D, RESPONSIBILITIES OF DHS I OHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct, to the extent authorized by this MOU a Automated verification checks an alien employees by electronic means, and Psife Yof I I f. verily MOU f0t Errotoyets I Rewsilon Date 06,01113 9 Page 4623 of 7162 h-Verm1fy___&a Company (D Number: O-S962 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security iDHS) and the Mitchell & Stark Construction Co, Inc. (Employer) The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E Verrfy. F,Verify is a program that electronically confirms an employee's eligibility to work in the United Statet, after completion of Form 1-9, Employment Eligibility Verification (Form. 1.9) This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer the Social Security Administration (SSA), and DHS Authority for the E -Verify program is found in Tale IV, Subtitle A of the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA). Pub L 104-208, 110 Stat 3009. as amended (8 U S C 1324a note) The Federal Acquisition Regulation (FAR) Subpart 22 18. "Employment Eligibility Verification' and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal cunifactor) to use E-Verify to verity the employment eligibility of certain employees working on Federal contracts ARTICLE 11 RESPONSIBILITIES A RESPONSIBILITIES OF THE EMPLOYER 1 The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system a Notice of E-Verify Participation L) Notice of Right to Work 2 T fit Employer agrees to provide to the SSA and DHS the names. titles, addresses, and telephone numbers of the Employer representatives to be contacted about E-Verify The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes 3 The Employer agrees to grant E-Verify access only to current employees who need E -Verify access Employers must promptly terminate an employee's E-Verify access it the employer is separated from the company or no longer needs access to E-Verify rb9t 1 Of ' 7 C,Vet4 MOO 104 Fmt*qtfa I Revs on Date 06,MO 0 Page 4624 of 7162 Ct>mpan) ID Number: 99962 4 The Employe( agrees to become familiar with and comply with the most recent version of The E-Verify User Manual. 5 The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases a The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E -Verify in order to continue using E•Verity. Failure to complete a refresher Tutorial will prevent the Employer Representative from continued use of E -Verity 6 The Employer agrees to comply with current Form 1-9 procedures, with two exceptions a If an employee presents a *List W identity document the Employer agrees to only accept "List G` documents that contain a photo. (List 6 documents identified in 8 C F.R § 274a 2(b)(1)(B)) can be presented during the Form 1-9 process to establish identity ) If an employee objects to the photio, requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218 b If an employee presents a DHS Form 1-551 (Permanent Resident Card), Form 1-766 Employment Authorization Document), or U S Passport or Passport Card to complete Form 1,9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employees Form 1-9 The Employer will use the photocopy to verity the photo and to assist DHS with its review of photo Mismatches That employees contest DHS may in the future designate other documents that activate the photo screening tool Note Subject only to the exceptions noted previously in this paragraph, employees still retain the right to present any List A or List 8 and L,sl C, documeniis) to complete the Form 1-9 7 The Employer agrees to record the case verification number on the employee's Form 1-9 or to print the screen containing the case verification number and attach 0 to the employee's Form 1,9 6 The Employer agrees that, although it participates in E-Verify. the Employer has a responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from otl,wt requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 2748 of the INA with respect to Form 1-9 procedures a The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the INA (1) List 8 identity documents must have photos, as described in paragraph 6 above, (2) When an Employer confirms the identity and employment eligibility of newly hired employee using E -Verify procedures, the Employer establishes 8 rebuttable presumption that it has not violated section 274A(ay 1)(A) of the immigration and Nationality Act (INA) with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that petsuo, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and $1,100 for each failure to notify DHS of continued employment following a final nonconfirmation; (4) It the Employer continues to employ an employee after receiving a final nonconfirmalion, then the Employe( is subject to a rebuttable presumption that it has knowingly i'age 2. it!? IF Vvofy WOO 1W I`MVOyets Revmol Date 0610F I 0 Page 4625 of 7162 Company ID Number: OW9 2 employed an unauthorized alien in violation of section 274A(a)(1)(A)., and (5) no E-Verify participant is civilly of criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b DHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verity. 9 The Employer is strictly prohibited from creating an E-Verify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed The Employer agrees to create an E-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections I and 2 of Form 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual If E -Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate The Employer's attempting in good faith, to make inquiries during the period of unavailability 10 The Employer agrees not to use E -Verify for pre -employment screening of job applicants, in support of any unlawful employment practice or for any other use that this MOU of the E-Verify User Manual does not authorize I I The Employer must use F-Verity lot all new employees The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article 11.8 of this MOU 12 The Employer agrees to follow appropriate procedures (see Article III Wow) regarding tentative nonconfirmations The Employer must promptly notify employees in private of the finding , and provide them with the notice and letter containing information specific to the employee's E-Verify case The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding. and not take adverse action against employees if they choose to contest the finding, while their case is still pending Further, when employees contest a tentative nonconfirmalion based upon a photo mismatch, the Employer must take additional steps see Article 1116 below) to contact DHS with information necessary to resolve the challenge 13 The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DHS is processing the verification request unless the Employer obtains knowledge (a5 defined in 8 C,F R j 274a.1(1)) that the employee is not work authorized, The Employer understands that an initial inability of the SSA or DHS automated verification system to verity work authorization, a tentative nonconfirmation, a case in continuance indicating the need for additional time for the government to resolve a case), of the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employ(-(., is not work authorized In any of such cases, the employee must be provided a full and fait opportunity to contest the finding. and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employees perceived employment eligibility status P09t lol 17 f,Vw,ff* KAOt loY Fm,piovefs ! Rewson uaie o6uwa e Page 4626 of 7162 E-Verify______ sor, Company ID Number 99962 including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued, It the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment Employers or employees with questions about a final nonconfirmation may call 8-Verify at 1-888,464- 4218 (customer service) or 1-888-897-7781 (worker hotline) 14 The Employer agrees 10 comply with Title VII of the Civil Rights Act of 1964 and section 2748 of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his of her national origin or citizenship status or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E -Verify except as provided in part 0 below, or discharging or refusing to hire employees because they appear or sound foreign` or have received tentative nonconfirmations The Employer further understands that any violation of the immigration -related unfair employment practices provisions in section 2748 of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII Gould subject the Employer to back pay awards compensatory and punitive damages Violations of either section 274B of the INA or Title VH may also lead to the termination of its participation in E-Verify. If the Employer has any questions relating to the anti -discrimination provision, it should contact OSC at 1.800-255-8155 or 1-800.237-2515 (TDD) 15 The Employer agrees that it will use the information it receives from E-Verdy only to confirm the employment eligibility of employees as authorized by this MOU The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU except for such dissemination as may be authorized in advance by SSA or DHS for legitimate purposes 16 The Employer agrees to notify DHS immediately in the event of breach of personal information Breaches are defined as loss of control or unauthorized access to E Verify personal data All suspected or confirmed breaches should be reported by calling 1-888464-4218 of via email at E-Veirifv0dhs oov Please use 'Privacy Incident - Password' in the subject line of your email when sending a breach report to E -Verity 17 The Employer acknowledges that the information it receives from SSA is governed by the Privacy Act (5 U S C § 552a(i)(1) and (3)) and the Social Security Act (42 U S C 1306(a)). Any person who obtains this information under false pretenses or uses it for any purpose other than as, provided for in this MOU may be subject to criminal penalties 18 The Employer agrees to cooperate with DHS and SSA in their compliance monitoring and evaluation of E -Verify, which includes permitting DHS SSA, their contractors and other agents, upon Wage 4 or 1 r f V-fv MOU to, l-P1-Y&s,, Rewmon Date DbVii;i 0 Page 4627 of 7162 Company l!CiNurribev 99%2 reasonable notice, to review Forms 1.9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verity. and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19 The Employer shall not make any false of unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media The Employer shall not describe its services as federally -approved, federally -certified, or federally -recognized, or use language with a similar intent on its website of other materials provided to the public Entering into this MOU does not mean that E-Verity endorses or authorizes your E-Verify services and any claim to that effect is false 20 Tate Employer shall not state in its websile or other public documents that any language used therein has been provided or approved by OHS, USCIS or the Verification Division without first obtaining the prior written consent of DHS 21 T'he Employer agrees that E-Verify trademarks and logos may be used only under license by DHS/USCIS (see M-795 (Web}) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services. products, wellosiles, of publications are sponsored by, endorsed by, licensed by, or affiliated with DHS USCIS or E -Verify 22 The Employer understands that it it uses E Verify procedures tot any purpose other than as authorized by this MOU. the Employer may be subject to appropriate legal action and termination of its participation in E-Verify according to this MOU B. RESPONSIBILITIES OF FEDERAL CONTRACTORS I It the Employer is a Federal contractor with the FAR E.-Verityclause subject to the employment verification terms in Subpart 22 18 of the FAR, it wit! become familiar with and comply with the most current version of the E -Verify User Manual lot Federal Contractors as well as the E -Verity Supplemental Guide for Federal Contractors 2 In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22 18 of the FAR it must verify the employment eligibility of any 'employee assigned to the contract' (as defined in FAR 22 1801) Once an employee has been verified through E-Verity by the Employer. the Employer may not create a second case for the employee through E-Verify a An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, wilhin 90 days of enrollment, begin to verify employment eligibility of new hires using E-Verify The Employer must verify those employees who are working in the United Slat", whether or not they are assigned to the contract Once the Employer begins verifying new hires such verification of new hires must be initiated within three business days after the hire date Once enrolled in E-Verify as a Federal contractor. the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enroitmew or within 30 days of an employee's assignment to the contract. whichever date is later Page I of'? f VeMy Mou for Employers I tit, am#1 Date 0WO 103 0 Page 4628 of 7162 Vorify--a Company ID Number 90-%2 b Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire If the Employer is enrolled in E.-Verity as a Federal contractor for 90 calendar days or lest, at the time of contract award. the Employer must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract Such verification of new hires must be initialed Within three business days after the date of hire. An Employer enrolled as a Federal contractor in E -Verity must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later. c Federal contractors that are institutions of higher education (as defined at 20 US C I Do 1 (a)), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency tinder a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however elect to verity all new hires, and/or all existing employees hired after November 6. 1986 Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employees assignment to the contract, whichever date is later a Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United Slates who were hired after November 6, 1986, instead of verifying only those employees assigned to a Covered Federal contract After enrollment, Employers- must elect to verify existing staff following DHS procedures and begin E -Verity verification of all existing employees within 180 days after the election e The Employer may use a previously completed Form 1-9 as the basis for creating an E -Verify case for an employee assigned to a contract as long as That Form 1-9 is complete (including the SSN) and complies with Article 11 ,A 6 it The employee's work authorization has not expired and fit The Employer has reviewed the Form 1-9 information either it) person or in communications with the employee to ensure that the employee's Section 1, Form 1 -9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U S citizen) I The Employer shall complete a new Form 1•9 consistent with Article If. A 6 or update the, previous Form 1-9 to provide the necessary information 4, t The Employer cannot determine that form i-9 complies with Article 11 A.6, ii, The employee's basis for work authorization as attested in Section 1 has expired or changed, or iir The Form 1.9 contains no SSN or is otherwise incomplete Note If Section I of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies w,th Pige t of I 1 f Ven'y OA>j to, IF mokiyers Re vi!,ivi Wit, 060 I,! 0 Page 4629 of 7162 Company ID Number, 99%2 Article 11 C,5, but reflects documentation (such as a U.S passport or Form 1-551) that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article 11,A.5, subject to any additional or superseding instructions that may be provided on this subject in the E-Verify User Manual 9 The Employer agrees not to require a second verification using E-Verity of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3 The Employer understands that d it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities unde! this MOU to contracting officers of other officials authorized 10 review the Employer*s compliance with Federal contracting requirements C, RESPONSIBILITIES OF SSA 1. SSA agrees to allow OHS to compare data provided by the Employer against SSA's database SSA sends DH'_- confirmation that the data sent either rnatches or does not match the information in SSA's database 2 SSA agrees to safeguard the information the Emptuyet provides through E-Verify procedures SSA also agrees to limit access to such information as is appropriate by law, to individuals responsible for the verification of Social Security numbers of responsible for evaluation of E -Verify or such other persons or entities who may be authorized by SSA as govemed by the Privacy Act (5 U S C § 552a), the Social Security Act (42 Ul 5 C 1306(a)), and SSA regulations (20 CFR Pall 401) 3 SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry E-Verify provides the information to the Employer. 4 SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence If the employee visits all SSA field office within the eight Federal Government work days from the date of referral to SSA. SSA agrees to update SSA records, if appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary In such cases, SSA will provide additional instructions to the employee, It the employee does not visit SSA in the time allowed, E-Verify may provide a final nonconfirmation to the employer. Note, If an Employer experiences technical problems. or has a policy question, the employer should contact E-Verify at 1.888-464-4218 D. RESPONSIBILITIES OF OHS 1 OHS agrees to provide the Employer with selected data from OHS databases to enable the Fmployer to conduct, to the extent authorized by this MOU. a Automated verification checks on alien employees by electronic means. arid POW 7 01 11 t Vt-14Y MOU fol EnVoyers I Rev-skon DAle 061D I I 3 a Page 4630 of 7162 Company ID Number; 99962 b, Photo verification checks (when available) on employees 2. DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verity. DHS agrees to provide the Employer names, titles, addresses, and telephone numbers of DNS representatives to be contacted during the E-Venty process 3 DHS agrees to provide to the Employer with access to E Verity training materials as well as an E-Verity User Manual that contain instructions on E-Verity policies. procedures and requirements lot both SSA and DHS. including restrictions on the use of E-Verify 4 DEIS agrees to train Employers on all important changes made to E.-Verity through the use of mandatory refresher tutorials and updates to the E-Verify User Manual Even without changes to E -Venfy DHS reserves the right to require employers to take mandatory refresher tutorials 5 DHS agrees to provide to the Employer a notice which indicates the Employer's participation in E-Venfy DHS also agrees to provide to the Employer anti-citiscriminalion notices issued by the Office of Special Counsel for Immigration- Related Unfair Employment Practices (OSC). Civil Rights Division, U S Department of Justice 6 DHS agrees to issue each of the Employer's E-Verify users a unique user identification number and password that permits them to log in to E -Verily 7 DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E-Venfy, or to such other persons or entities as may be authorized by applicable law Information will be used only to verity the accuracy of Social Security numbers and employment eligibility to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements 8 DHS agrees 10 provide a means of automated verification that provides (in conjunction with SSA verification procedures) confirmation or tentative nonconfirmation of employees* employment eligibility within three Federal Government work days of the initial inquiry 9 DHS agrees to provide a means of secondary verification (including updating DHS records) for employees who contest DHS tentative nonconfirmations and photo mismatch tentative nonconfirmal ions This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS. unless DHS determines that more than 10 days may be necessary. In such cases, DHS will provide additional verification instructions ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND OHS A. REFERRAL TO SSA I If the Employer receives a tentative nonconfirmation issued by SSA. the Employer must print the notice as directed by E -Verify The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify r'agk e Of 17 1 VWy KK)U fo, Employers ; Rev1pon r)jne 06r01r13 0 Page 4631 of 7162 Company ID Plumber: 99962 b Photo verification checks (when available) on employees. 2 DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. DHS agrees to provide the Employer names, titles, addresses, and telephone numbers of OHS representatives to be contacted during the E -Verify process 3 DHS agrees to provide to the Employer with access to E4erify training materials as well as an E-Verity User Manual that contain instructions on E-Verify policies. procedures, and requirements for both SSA and OHS, including restrictions on the use of E-Verity 4 DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify Use( Manual Even without changes to E -Verify. DHS reserves the right to require employers to take mandatory refresher tutorials 5 DHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E - Verify DHS also agrees to provide to the Employer anti -discrimination notices issued by the Office of Special Counsel for Immigration -Related Unfair Employment Practices (OSC), Civil Rights Division U S Department of Justice 6 DHS agrees to issue each of the Employer's E -Verify users a unique user identification nurnt*r and password that permits them to log in to E-Verify 7 DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E Verify. or to such other persons or entities as may be authorized by applicable law Information will be used only to verify the accuracy of Social Security numbers and employment eligibi!ity, to enforce the INA and Federa! criminal laws, and 10 administer Federal contracting requirements 8 DHS agrees to provide a means of automated verification that provides (in conjunction with SSA verification procedures} confirmation or tentative nonconfirmation of employees' employment eligibility within three Federal Government work days of the initial inquiry 9 OHS agrees to provide a means of secondary verification (including updating DHS records) for employees who contest OHS tentative nonconfirmations and photo mismatch tentative nonconfirmations This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS, unless DHS determines that more than 10 days may be necessary, In such cases, DHS will provide additional verification instructions ARTICLE III REFERRAL OF INDIVIDUALS 10 SSA AND DHS A, REFERRAL. TO SSA I If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify The Employer must promptly notify employees in private. of the finding and provide them with the notice and letter containing information specific to the employee's E-Verity f'a9c F, 0 17 E Ycri'y MOU fo, frnpwem I Rev,-,V) [Wo 04I0103 C0A, 0 Page 4632 of 7162 E -Verify *. r Company ID Number: 9"62 case The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he of she will contest the tentative nunconfirniation as soon as possible after the Employer receives the tentative nonconfirmation Only the employee may determine whether he or she will contest the tentative nonconfirmation 3 After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed byE-Verdy The Employer must record the case verification number, review the employee, information submitted to F -Verify to identify any errors, and find out whether the employee contests tt)e tentative nonconfirmation The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again it this review indicates a need to do so 4 The Employer will instruct the employee to visit an SSA office vvithw eight Federal Government woo days SSA will electronically transmit the result of the referral to the Employee within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary 5 While waiting for case results, the Employer agrees to check the F-Verify system regularly for case updates 6 The Employer agrees not to ask the employee lociblaina printout from the Social Security Administration number database (the Numident) or other written verification of the SSN from the SSA 8, REFERRAL TO DHS I If the Employer receives a tentative nonconfirmation issued by DHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency 10 employees The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending 2 The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation Only the employee may determine whether he of she will contest the tentative nonconfirmation 3 The Employer agrees to refer individuals to OHS only when the employee chooses to contest a tentative nonconfirmation 4 If the employee contests a tentative nonconfirmation issued by OHS, the Employer will instruct tt* Paqt !. ("I I E ytsity mot j It,, fmrbyrft I Revoo. Wit Wo I, Vj Gl Page 4633 of 7162 Company ID Number 99%2 employee to contact OHS through its toll -free hotline (as found on the referral letter) within eight Federal Government work days, 5 It the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph 1 at this section for tentative nonconfirmations, generally 6 The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1-551, Form 1.766 US Passport, or. passport card to OHS for review by: a Scanning and uploading the document, or b Sending a photocopy of the document by express mail (furnished and paid for by the employer) 7 The Employer understands that it it cannot determine whether there is a photo triatchimismatch, the Employer must forward the employee s documentation to OHS as described in the preceding paragraph The Employer agrees to resolve the case as specified by the OHS representative, who will determine the photo match or mismatch 8 DNS will electronically transmit the result of the referral to the Employer within W Federal Government work days of the referral unless it determines that more than 10 day-, is necessw-y 9 While waiting for case results, the Employer agrees to check the E -Venty system regularly for case updates ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1 SSA and OHS will not charge the Employer for verification services performed under this MOU The Employer is responsible for providing equipment needed to make inquiries To access E-Verity, an F mployer will need a personal computer with Internet access ARTICLE V MODIFICATION AND TERMINATION MODIFICATION 1 This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and OHS operates the, E ..Verity program unless modified in writing by the mutual consent of all parties 2 Any and all E -Verity system enhancements by OHS or SSA, including but not limited to E-Verify checking against additional data sources and instituting new verdicalion policies of procedures, will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes Pikt ,,4t, 10 (,111[ •vtrt!y Moo for F.rrvio*ers Rev soon Dait Da Olt13 0 Page 4634 of 7162 E-Veriwf y ------------ Company ID Number: 99962 employee to contact OHS through its toll -free hotline (as found on the referral letter) within eight Federal Government work days. 5 If the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph I of this section for tentative nonconfirmations, generally. 6 The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1.551, Form 1-766, U S. Passport, or passport card to OHS lot review by. a Scanning and uploading the document, or b Sending a photocopy of the document by express mail (furnished and paid for by the employer) 7 The Employer understands that if it cannot determine whether there is a photo matc h/m is match, the Employer must forward the employee s documentation to DHS as described in the preceding paragraph The Employer agrees to resolve the case as specified by the OHS representative mic will determine the photo match or mismatch 8 OHS will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary 9 While waiting for case results the Employer agrees to check the E Verily system regularly for case updates ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1 SSA and OHS will not charge the Employer for verification services performed under this M00 The Fniployer is responsible for provicl ng equipment needed to make inquiries To access F-Verity, an Employer will need a personal computer with Internet access ARTICLE V MODIFICATION AND TERMINATION A MODIFICATION I This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and OHS operates the E-Verity program unless modified in writing by the mutual consent of ali parties 2 Any and all E -Verity system enhancements by OHS or SSA, including but not limited to E-Verity checking against additional data sources and instituting new verdiralion policies or procedures, will be covered under this MOU and will not Cause the need for a supplemental MOU that outlines these changes PiV 100 17 T Vtl,S WX 110, kmoloY&rs keww" Dale 06:O V1 I a Page 4635 of 7162 IT"", E'Vermify......o", Company ID Numbtt: W%? B. TERMINATION I The Employer may terminate this MOU and its participation in E-Verify at any time upon 30 days prior written notice to the other parties. 2, Notwithstanding Article V, part A of this MOU, DHS may terminate this MOU, and thereby the Employer s participation in E -Verity. with or without notice at any time if deemed necessary because of the requirements of law or policy, or upon a determination by SSA of DHS that there has been a breach of syslery, integrity or security by the Employer, or a failure on the part of the Employer to comply wilt) established E-Verify procedures and/or legal requirements The Employer understands that it 11 is a Federal contractor, termination of this MOU by any party for any reason may negatively affect the performance of its contractual responsibilities Similarly. the Employer understands that it it is in a stale where E-Verify is mandatory termination of this by any party MOU may negatively affect the Employer's business 3 An Employer that is a Federal contractor may terminate this MOU when the Federal contract that requires its participation in E-Ver4 is terminated or completed In such cases, the Federal contractor must provide written notice to DHS If an Employer that is a Federal contractor fail$ to provide such notice. then that Employer will remain an E-Verily participant, will remain bound by the terrns of this KIOU that apply to non -Federal contractor participants, and will be required to use the E-Verity procedures to verity the employment eligibility of all newly hired employees 4 The Employer agrees that E-Verity is not liable for any losses. financial or otherwise, if the Employer is terminated from F. -Verity ARTICLE VI PARTIES A Some of all SSA and DHS responsibilities under this MOU may be performed by contractor(s), and SSA and DHS may adjust verification responsibilities between each other as necessary By separate a( gieeffient with DHS, SSA has agreed to perform its responsibilities as described in this MOU B Nothing in this MOU is intended, or should be construed, to create any right or benefit, substantive of procedural, enforceable at law by any third party against the United States, its agencies. officers, of employees, or against the Employer, its agents, officers, or employees C The Employer may not assign, directly or indirectly, whether by operation of law, change of control of merger, all or any part of its rights or obligations under this MOU without the prior written consent of DHS, which consent shall not be unreasonably withheld or delayed Any attempt to sublicense, assign, or transfer any of the rights, duties, or obligations herein is void D. Each party shall be solely responsible for defending any claim or action against it arising out of or related to E-Verify or this MOU, whether civil or criminal, and for any liability wherefrom, including (but not limited to) any dispute between the Employer and any other person or entity regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by the Employer. E The Employer understands that its participation in F -Verify is not confidential information and may be disclosed as authorized of required by law and DHS or SSA policy, including but not limited to, pa'gir' 71 of I I t Ve-My MOt I for EMvryeft J Rrw's of Dale 06"01,13 0 Page 4636 of 7162 T- Company ID Number; 99962 Congressional oversight, E-Verify publicity and media inquiries, determinations of compliance with Federal contractual requirements, and responses to inquiries under the Freedom of Information Act FOIA) F. The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer and DHS respectively The Employer understands that any inaccurate statement, representation data or other information provided to DHS may subject the Employer, its subcontractors, its employees, or its representatives. to (1) prosecution for false statements pursuant to 18 U S,C 1001 and/or; (2) immediate termination of As MOU and/or; (3) possible debarment or Suspension G The foregoing constitutes the full agreement on this subject between DHS and the Employe? To be accepted as an E-Verify participant, you should only sign the Employer's Section of the signature page, If you have any questions, contact E-Verity at 11.888-464-4218. Flaw I J 0 P t-Vk"N Moil Iw f. ?T,Plo*fs 1 041(, ot)()1,13 0 Page 4637 of 7162 mfyh-Verl Company ID Number, 499t2 Approved by: Mitchell b Stark COnSlrUgrOM Go Inc ame tease Type or Print) title t,attne w J rtti tg Signature baie I EtectroncOy S9nt c 02013r2038 Department of Homeland Security - Ve-attcatietn bivision' rvame triease 1 ype or Nn UsCis veni"Ion Q. tirS Cr i5lgnatU(e Elecuoncai y Sr ryea I agt 13 0 , i E ven`y MOU to, C mptuyers i Rt'.SQ1 bate 0&-01313 Date 02 t W006 0 Page 4638 of 7162 E-Ver1mfy,.,-.* Company 10 Number: 99962 Information Required for the E-Verify Program i relating to your Company'. Mitchell 8 Stark Construdion Co . inc pany Name 170 Wesi First Si Medcra. IN 47260 Company Facility Address PC Box 719 Medora IN 47260 ompany Alternate Address i iCounty or Parish JACKSON lEmployer Identification Number 350%4820 North American Industry Classification Systems Code 237 a rent Company i umber of Employees 1 100In 499 umber of Sites Verified for 2 pas'} 14 of t It Versr-y k".) Ir E mptoy@IS I Rea,I w'. Dale 06 0va5 0 Page 4639 of 7162 lift f ----------- er C—Pany 11) NumWv 99962 Are you verifying for more than I site's If yes, please provide the number of site's verified for in each State: F L' ORI DA I S#1ej5) NVIANA I sde(s) 17 1 VCOY MOU, N! F Vlcyen I Reos*r) Owe Owf)sm 5 0 Page 4640 of 7162 COMPanY 10 Nurmbtt: 99962 Information relating to the Program Administrator(s) for Your Company on Policy questions otoperationalproblems: Ne're Connie sparks Phone Nurnber 812) 966 2151 Fax Nvmtet 812) 966 - 2862 F mad Aadre!,s tsparksprnilcheliSlark Cory, Name 84nOa Burgbachei Phone Number U39) 597 , 2165 ex1 28 Fax Nurnt*, 239) 566 7865 I rna,? Address bburQba,-hei@m tcheiistaq Corn Na'—Oc- Matthew J Helwwj Plvwle NjmDer 812) 966 2151 Pay Numbe, 812) 966 - 2862 Ern3,1 Address Mhewo9m,tctleilstark Corr: Name Ela Caniv,, Phone Number 239) 597 2165 exi 24 Pay Number 239) 566 7865 trnwl Address PcarnPs@rn;jChe1j$ta6. Corr. age 16 01 17 F NN Mau for frnp*yersLert C*'Jo 1! 13 OCA () Page 4641 of 7162 COMP211Y 10 Number qW2 Page intentionally left blank Page, I? of! 7 F Vvty fjM, tor fnpjt),tFj I kewt,0,1 U,ft 06,'O it I i 0 Page 4642 of 7162 2,Q FK,,.IGN _ROFIT CORPORATION ANN IAL'2EPORT DOCUMENT# 845897 Entity Name: MITCHELL & STARK CONSTRUCTION CO„ INC, Current Principal Place of Business: 170 W FIRST STREET MEDORA, IN 47260 Current Mailing Address: P.O. BOX219 MEDORA, IN 47260 FEI Number: 35.0964820 Name and Address of Current Registered Agent: PENNER, BRIAN R 6001 SHIRLEY STREET NAPLES, FL 34109 US FILE© Apr 13, 2020 Secretary of State 8439119228CC Certificate of Status Desired: No The above named entity submits this statement for the purpose of changing its registered offtcc or registered agent, or bath, in the State of Fionda. SIGNATURE: Electronic Signature of Registered Agent Date Officer/Director Detail : Title TREASURER Name HARRISON. FRED C Address 6236 WEST CR 50 NORTH City -State -Zip: MEDORA IN 47260 Title VAS Name SCAFIDI, DAVID C Address 2229 SW 50TH STREET City -State -Zip: CAPE CORAL FL 33914 Title DIRECTOR Name PENNER, JEANNE M Address 6540 HUNTERS ROAD City -State -Zip: NAPLES FL 34109 Title ASST SECRETARY Name PENNER, MITCHELL KEITH Address 6540 HUNTERS ROAD City -State -Zip: NAPLES FL 34109 Title PRESIDENT Name PENNER, BRIAN R Address 6540 HUNTERS ROAD City -State -Zip: NAPLES FL 34109 Title VAS Name WESTHAFER, MICHAEL P Address 4510 PINE ROAD City -State -Zip: FORT MYERS FL 33908 Title ASST. SECRETARY Name SPARKS, CONNIE S. Address 367 E. STATE ROAD 250 City -State -Zip: BROWNSTOWN IN 47220 I hetaof ::e!tiJy trial the iR/Grmaflon Indicated on. 1W rerlan (N sUppJe!nHntH! rHpi)!/ 15 true Hno .ict:urate and ihat My Nki4Y!<i/MC signature shall have the same fegai Hfrect as d made Gllda! oath, that f anion olyleer of dir(rctor of pre corporanorl or it* receiver of frustee er!rpvwoted tc execute this report as required by Clulpfel 607, Ffortda Statute,,; and that my name appeals above, of or; an aftaehment With alt other like ell1polvered, SIGNATURE: BRIAN PENNER PRESIDENT 04/13/2020 Electronic Signature of Signing Officer/Director Detail Date 0 Page 4643 of 7162 Detail by Entity Name Page |of3 oemotl f:,FoCAPO=nONo http://scarch.aunbizoru/ nqoirv/CorporationSeu,ch/SeurchRcsult[eta|?inqui — 6/23/2020 0 Page 4644 of 7162 Detail by Entity Name Page 2 of 3 6540 HUNTERS ROAD NAPLES, FL 34109 Title VAS SCAFIDI, DAVID C 2229 SW 50TH STREET CAPE CORAL, FL 33914 Title VAS WESTHAFER, MICHAEL P 4510 PINE ROAD FORT MYERS, FL 33908 Title Director PENNER,JEANNE M 6540 HUNTERS ROAD NAPLES, FL 34109 Title Asst. Secretary SPARKS, CONNIE S. 367 E. STATE ROAD 250 BROWNSTOWN, IN 47220 Title Asst. Secretary PENNER, MITCHELL KEITH 6540 HUNTERS ROAD NAPLES, FL 34109 Annual Reports Report Year Filed Date 2018 01/10/2018 2019 01 /06/2019 2020 04/13/2020 Document Images 0411312020 -- ANNi1AL REPORT vow Image m PDF format Qi Igg,12G. I 1 --.ANNUAL REPORT View nnage in PDF' format 0111012018 —ANNUAL REPORT[ View image in PDF format 01/06/2017 --ANNUAL REPORT View image in PDF format 02l04120i6 -- ANNUAL REPORT View image in PDF formal Q6/02J2q' ` -- ANNUAL REPORT" View image in Pt)F format 02l24/2014 -- ANNUA!_ REPORT View image in PDF format U6/23120 3 -- ANNU,0.L_REPQRT I View. image: in PDF format 04/2L/2r,122--ANNUAL EEPORT View image; in PDP' fomlat f)2/2512011 --ANNUAL REPORT View image in PDF format 02115/20,10 — ANNUAL REPORT View image in PDF format 0 v, http://search.sunbiz.org/inquiry/CorporationSearch/SearchResultDetaiI?inquirytype=Entity... 6/23/2020 Page 4645 of 7162 Detail by Entity Name Page 3 of 3 0112612CG9 -- ANNUAL REPORT View image in PDF format Q,111 1 f; CO,L+ - ANNI IL R„_„_„ FAT View ,mage in PDfformat 011081200' -- ANNUAL REPORT View image in PDF format 02t031' 0 '8 —ANNUAL REPORT View image in PDF format 01110/ 2005 -- ANNUAL REPORT View image in PDF format 02. 113/2004+— ANNUA.. REPORT ' View image in PDF Format 02/ 03/2003 -. ANNUAL.. REPORT View image in ?LiF format G211 % 12G02 - ANNUAL. REPORT View image in PCJ: fouriat QDR . ZI1! G1?...--./.NNU.A..L tEPQRT Vier image: in PDF format O i25/2GL! --ANNUAL REF!QkT View imago in t'i:ii' format G2727/" 99 ^ -- ANNUAL REIPORT View irr:age i!i i'CiF: format 0210. 511998 -- ANN AL. REPORT View image in PUP format 12/ 04/1497 -- ANNUAL REPORT View image in PDF format Gr/. 711^:. 9_=.ANNLQALRF;E'CJRT, View image in PDF formate 01'./ 1''/1 Q5 -- ANNUL( f2F;i?C i2T View image in PDF format oeca: nnenc of state, e::+ac:, W :-c: p :miens http: // search.sunb iz.orgll nquirylCorporati on S earch/S earchResultDetai 1?inquirytype=Entity... 6/23/2020 Page 4646 of 7162 i M 3 f 4i w c, J u u 0[ Dw CS Ln fry vt 1 w w W d Z U, 0 z z a ¢ n o L O vw V) LL Q Z 00 ry 0 u . t!1 - CI o too a) UJ ON V 00 v p LLJ u c 0 c~n c W LL = ILO LL ® Z S w n- c o W © a w d W _ in 0 a w o m CO U U Z > inELLLLJULU V =< V) C - w w z w p uj0 Q w a _ o G yyp ui TreuR i 4# NIMIIY r 5r E 0 Page 4647 of 7162 EXHIBIT A-3: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Brandon Tripp Josh Peterson Personnel Category Construction Superintendent Project Manager 10 Construction Services Agreement: Revised 072118 (v6) Page 4648 of 7162 Zurich North America Surety lzgg Zurich Way Schaumburg, IL. 6o196 http://www.zurich.com Phones-800-876-z616 Ext4882 317-816-4882 Direct Fax 317-816-4899 E-Mail anthony.ortman@zurichna.com 0 ZURICH July 1, 2020 Collier County Board of Commissioners 3299 Tamiami Trail East, Suite 303 Naples, Florida 34112 RE: BID NO.20-7769 SCRWTP REACTOR TANK 4 BOND NO.9304565 Gentlemen: We are authorizing the issuance of the required Performance and Payment bonds at the request of Mitchell & Starks Construction Co., Inc. The Performance and Payment bonds will be issued undated. Fidelity & Deposit Company of Maryland authorizes Mitchell & Stark Construction Co., Inc. or whomever they designate to date the bonds and the powers -of -attorney once the contract date has been determined. We anticipate that the date will be around July 31, 2020. Since dert i li t Attorney In Fact and Agent Page 4649 of 7162 EXHIBIT B-1: PUBLIC PAYMENT BOND ITB# 20-7769 Bond No. 9304565 Contract No. 20-7769 KNOW ALL MEN BY THESE PRESENTS; That MITCHELL & STARK CONSTRUCTION CO., INC. 6001 SHIRLEY STREET NAPLES, FLORIDA 34109 as Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND , as Surety, located at 1299 ZURICH WAY SCHAUMBURG, IL. 60196 (Business Address) are held and firmly bound to COLLIER COUNTY BOARD OF COMMISSIONERS as Obligee in the SUM Of THREE MILLION EIGHT HUNDRED FORTY-THREE THOUSAND DOLLARS AND NO CENTS ($ 3,843,000.00 _) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of JULY 2020 with Obligee for BID NO.20-7769 SCRWTP REACTOR TANK 4 in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal; Promptly makes payment to all claimants as defined in Section 255.05(9), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of fect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this 4 . day of JULY 2020 , the name of each party being affixed and these presents duly signed by its under -signed representative, pursuant to authority of its governing body. 11 Construction Services Agreement: Revised 072118 (v6) Page 4650 of 7162 Signed, sealed and delivered in the presence of: esses as to Principal STATE OF-- COUNTY OF PRINCIPAL MITCHELL & STARK CONSTRUCTION CO., INC. BY:`__—. NAME: BRIAN PENNER ITS: CEO r z . ":.z.. The foregoing instrument was acknowledged before me by means of 9 physical presence or online notarization, this _I day of 3 -"f 20 ° L; , by of a corporation, on behalf of the corporation. He/she is personall known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: BELINDA BURGBACHER MY COMMISSION # GG 278246 EXPIRES: January 22, 2023 Bonded Thru Notary Public Underwriters AFFIX OFFICIAL SEAL) ATTEST: Wi lrassestd-ISurety REGINA WILLIAMS, ADMINISTRATIVE ASSISTANT nature of Notary Public) NAME !r Legibly Printed) Notary Public, State of f1 Commission No.: G (, .1'tg- .2 Y(— SURETY: FIDELITY AND DEPOSIT COMPANY OF MARYLAND Printed Name) 1299 ZURICH WAY SCHAUMBURG, IL. 60196 11 Bu 7'tZAddressl Authorized Signatu ) ROBERT E. WILLIAMS, JR. ATTORNEY IN FACT Printed Name) 12 Construction Services Agreement: Revised 072118 (v6) At) Page 4651 of 7162 OR n e s Zse:s: STATE OF COUNTY OF As Attorney in Fact Attach Power of Attorney) Printed Name) Business Address) Telephone Number) The foregoing instrument was acknowledged before me by means of 0 physical presence or online notarization, this day of —T 20 , by as Of to , , . ; , ,-t _ a a '. corporation, on behalf of the corporation. He/she is personaU known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: gnature of Notary Public) / Name: &"-Itl Al ! Legibly Printed) AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: III o<aY 9' BELINDABURGBACHER I ? ' MY COMMISSION # GG 278246 EXPIRES: January 22, 2023 rFOF F °c` Bonded Thru Notary Pubiic Underwriters 13 Construction Services Agreement: Revised 072118 (v6) O Page 4652 of 7162 ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"), by ROBERT D. MURRAY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint Robert E. WILLIAMS, JR., of Brownstown, Indiana, its true and lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of the By -Laws of said Companies, and is now in force. IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 1 st day of June, A.D. 2020. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND p SUk, 00;; Q)•aeroryf;sYnt Zy NI..a1MV- li Assistant Secretary Vice President Dawn E. Brown Robert D. Murray State of Maryland County of Baltimore On this Ist day of June, A.D. 2020, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, ROBERT D. MURRAY, Vice President, and DAWN E. BROWN, Assistant Secretary, of the Companies, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that he/she is the said officer of the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. Zi:' •fit aY ,:q tali Constance A. Dunn, Notary Public My Commission Expires: July 9, 2023 POA-F 044-3937A Page 4653 of 7162 EXTRACT FROM BY-LAWS OF THE COMPANIES Article V, Section 8, Attorneys -in -Fact. The Chief Executive Officer, the President, or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys -in -fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney -in -fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at any time. CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Article V, Section 8, of the By -Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney ... Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice -President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this day of 120. 0-1p, c----S(''y It*: x o_ SEAL Brian M. Hodges, Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT ALL REQUIRED INFORMATION TO: Zurich American Insurance Co. Attn: Surety Claims 1299 Zurich Way Schaumburg, IL 60196-1056 Page 4654 of 7162 EXHIBIT B-2: PUBLIC PERFORMANCE BOND IT13#20-7769 Bond No. 9304565 Contract No. 20-7769 KNOW ALL MEN BY THESE PRESENTS: That MITCHELL & STARK CONSTRUCTION CO., INC. 6001 SHIRLEY ST. NAPLES, FL. 34109 as Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND as Surety, located at 1299 ZURICH WAY SCHAUMBURG, IL 60196 Business Address) are held and firmly bound to COLLIER COUNTY BOARD OF COUNTY COMMISSIONERS as Obligee in the sum of THREE MILLION EIGHT HUNDRED FORTY THREE THOUSAND DOLLARS AND NO CENTS 3,843,000.00 ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the - l day of JULY 2020 with Obligee for BID NO. 20-7769 SCRWTP REACTOR TANK 4 In accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Performs the Contract at the times and in the manner prescribed in the Contract; and 2. Pays Obligee any and all losses, damages, costs and attorneys' fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of fect Sureties obligation unde r this Bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this I day of JULY , 20 20 , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 14 Construction Services Agreement: Revised 072118 (v6) Page 4655 of 7162 Signed, sealed and delivered in the presence of esses to Principal STATE OF 1t "tL ^- COU NTY OF PRINCIPAL MITCHELL & STARK CONSTRUCTION CO., INC. In NAME: BRIAN PENNER ITS: CEO The foregoing instrument was acknowledged before me by means of ff physical presence or online notarization, this I day of -1w y 202.: by as of corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did ( did not) take an oath. My Commission Expires: AFFIX OFFICIAL SEAL) G73246 1 EAf',i S. J.t^,;ary 22, 2C 3 1 1a%S=y Vtr rk ignature of Notary Public) r% Name: Legibly Printed) Notary Public, State of: Commission No.: GG V26te2 15 Construction Services Agreement: Revised 072118 (v6) Page 4656 of 7162 ATTEST: 4Witn s Sas to Surety REGINA WILLIAMS, ADMINISTRATIVE AS ISTANT Witness s STATE OF ate,' `` COUNTY OF La ) ) - FIDELITY AND DEPOSIT COMPANY OF MARYLAND Printed Name) 1299 ZURICH WAS SCHAUMBURG, IL. 60196 Bu ' Address) 1Authorized Signatur ROBERT E. WILLIAMS, JR. ATTORNEY IN FACT Printed Name) OR As Attorney in Fact Attach Power of Attorney) rintedName) l Business Address) Telephone Number) The foregoing instrument was acknowledged before me by means of Q5physical presence or online notarization, this I day of w iy 20 6 by of a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: I. iOPJ # GG 273,246 I y i t,lu• Urv'i AFFIX OFFICIAL SEAL) gnature of Notary Public) Legibly Prtnted) Notary Public, State of: Commission No.: 16 Construction Services Agreement: Revised 072118 (v6) 90( Page 4657 of 7162 ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Illinois, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Illinois (herein collectively called the "Companies"), by ROBERT D. MURRAY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint Robert E. WILLIAMS, JR., of Brownstown, Indiana, its true and lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of the By -Laws of said Companies, and is now in force. IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 1 st day of June, A.D. 2020. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND SEAL op-z". Assistant Secretary Vice President Dawn E. Brown Robert D. Murray State of Maryland County of Baltimore On this 1st day of June, A.D. 2020, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, ROBERT D. MURRAY, Vice President, and DAWN E. BROWN, Assistant Secretary, of the Companies, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that he/she is the said officer of the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. Constance A. Dunn, Notary Public My Commission Expires: July 9, 2023 POA-F 044-3937A Page 4658 of 7162 EXTRACT FROM BY-LAWS OF THE COMPANIES Article V, Section 8, Attorneys -in -Fact. The Chief Executive Officer, the President, or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attomeys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney -in -fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at anytime." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Article V, Section 8, of the By -Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney ... Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 1 Oth day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice -President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this day of 20 D DEIpy .00'. !si.,4. n. SEAL CO. 3 0ft 0__ Brian M. Hodges, Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT ALL REQUIRED INFORMATION TO: Zurich American Insurance Co. Attn: Surety Claims 1299 Zurich Way Schaumburg, IL 60196-1056 Page 4659 of 7162 EXHIBIT B-3: INSURANCE REQUIREMENTS The Contractor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Contractor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Contractor waive against each other and the County's separate Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Contractor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Contractors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number/contract number and title. The General Liability Policy provided by Contractor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Contractor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Contractor has any self -insured retentions or deductibles under any of the below listed minimum required coverage, Contractor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be Contractor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Contractor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non -renewal on the part of the insurance carrier or the Contractor. The Contractor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or material change in coverage or limits received by Contractor from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Contractor hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 17 Construction Services Agreement: Revised 072118 (v6) Page 4660 of 7162 Should at any time the Contractor not maintain the insurance coverage(s) required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage(s) and charge the Contractor for such coverage(s) purchased. If Contractor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Contractor under this Agreement or any other agreement between the County and Contractor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage(s) purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverage(s) shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Contractor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Contractor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 18 Construction Services Agreement: Revised 072118 (v6) 0 Page 4661 of 7162 Collier County Florida Insurance and Bonding Requirements Insurance / Bond Type Required Limits 1. Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof of exemption. An application for exemption can be obtained online at https://apps,fldfs.com/bocexempt/ 2. Employer's Liability $ single limit per occurrence 3. Commercial General Bodily Injury and Property Damage Liability (Occurrence Form) patterned after the current $ single limit per occurrence, $2,000,000 aggregate for Bodily Injury ISO form Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. Indemnification To the maximum extent permitted by Florida law, the Contractor/Vendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the ContractorNendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. 5. Automobile Liability $ Each Occurrence; Bodily Injury & Property Damage, Owned/Non-owned/Hired; Automobile Included 6. Other insurance as Watercraft $ Per Occurrence noted: United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. Per Occurrence Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Per Occurrence Aircraft Liability coverage shall be carried in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Per Occurrence Pollution Per Occurrence Professional Liability $ Per claim & in the aggregate 1,000, 000 per claim and in the aggregate 2,000,000 per claim and in the aggregate Project Professional Liability $ Per Occurrence Valuable Papers Insurance $ Per Occurrence 19 Construction Services Agreement: Revised 072118 (v6) ED Page 4662 of 7162 Cyber Liability $ Per Occurrence Technology Errors & Omissions $ Per Occurrence 7. Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 9. Consultant shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Consultant shall provide County with certificates of insurance meeting the required insurance provisions. 10. Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. 11. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12. Thirty (30) Days Cancellation Notice required. Consultant's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. Name of Firm Consultant Signature Print Name Insurance Agency Agent Name Date Telephone Number 20 Construction Services Agreement: Revised 072118 (v6) 0 Page 4663 of 7162 EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF (COLLIER) STATE OF (FLORIDA) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: 1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. 2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. 3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. 4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. Witness President Witness STATE OF COUNTY OF CONTRACTOR BY: ITS: DATE: Corporate Seal] The foregoing instrument was acknowledged before me by means of physical presence or online notarization, this day of , 20 by corporation. He/she is personally My Commission Expires: AFFIX OFFICIAL SEAL) as of corporation, on behalf of the known to me OR has produced as identification and did (did not) take an oath. Signature of Notary Public) NAME: Legibly Printed) Notary Public, State of Commissioner No.: 21 Construction Services Agreement: Revised 072118 (v6) Page 4664 of 7162 EXHIBIT D FORM OF CONTRACT APPLICATION FOR PAYMENT Collier County Board of County Commissioners the OWNER or Collier County Water -Sewer Owner's Project Manager's Name: Bid No. Project No. Count 's Division Name Purchase Order No. Submitted by Contractor Representative'. Name Application Date: Contractor's Name & Address: Payment Application No. Original Contract Time: Original Contract Price: Revised Contract Time: Total Change Orders to Date: Revised Contract Amount: Total Value of Work Completed & Stored to Date: Retainage @10% through [Insert Date] Retainage @ 10% through [Insert date] Retainage @ % after Insert date Less Retainage Total Earned Less Retainage Less previous payment(s Percent Work Completed to Date: AMOUNT DUE THIS APPLICATION: Percent Contract Time Completed to Date: Liquidated Damages to Be Accrued Remaining Contract Balance ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. Contractor's Name Contractor's Signature: Date: Type Title: Shall be signed by an authorized representative of the Contractor. to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Payment Professional's Name: Design Signature: Date: to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Payment Owner's Project Manager Name: Si nature: I I Date: 22 Construction Services Agreement: Revised 072118 (v6) Page 4665 of 7162 EXHIBIT D (Continued) SCHEDULE OF VALUES Project Name: Project Number: Date: Period To: ITEM NUMBER DESCRIPTION SCHEDULED VALUE WORK COMPLETED STORED MATERIALS TOTAL COMPLETEE STORED TO DATE PERCENT COMPLETE BALANCE TO FINISH 10% RETAINAGE RETAINAGE reduced rate) TOTAL RETANAGE WITHHELDPREVIOUSAPPLICATIONSTHIS PERIODTHRUDATESINCEDATE TOTALS Explanation for the two columns under Previous Applications: The Thru Date is where you will place all information until the contract is complete unless a release or reduction of retainage issue coi into play. If this happens, all information up to the date of the % change in retainage is placed in the Thru Date column. Information after that date is placed in the Since Date column. This states what has happened since the change in retainage. 23 Construction Services Agreement: Revised 072118 (v6) 9 Page 4666 of 7162 Exhibit D Continued) Stored Materials Record Formula: A+B-C- D=E A B C D E Date Description Supplier Invoice Number Previously Received Received This Period Previously Installed Installed This Period Balance To Install 24 Construction Services Agreement: Revised 072118 (v6) Page 4667 of 7162 EXHIBIT E: CHANGE ORDER An electronic data entry form may be found at: http://bccsr)01/SiteDirectoEy/ASD/Purchasing/Formsl/Forms/Default.aspx Change Order Form Contract : Changer:= Purc.has eOr Contractor!Firm Name: Project Manager Nacre er f: Project;,: Project Name: Department: CrtiEnsl "vni &c2` i«" Crder A,rncunt Original ECC. Appr-+ial Bat=; ^,genes ltar. A Current BCC AprxcvedAmcunt Last BCC Ap.l roval Date; Aaenda Item# Current ConiractANark Qrder Amount SAP Contract Expiration DabE fviastc-) C,Ibr Arnaurtaf this Change ocIWO! T taIChaNe f•cm Or'vjinaI Amount Revise- af-ontract'vr/cO, Ofdet Tutsl 0.3U fCI`,t J: C hangafro mCur;ert 2 C C ApprcvedArXIurt CumulaB-,&-Chen- gf--. 1.^0 C 114'311 ChangefromCurreriArnount e Completion Data, Description of the Tasks} Change, and Rationale for the Change Notice to Proc LI Original Last Approved Revised Date Date Completion Dat Date rofDaysAdded SelectT3sks Add newt3skts) Deletet35k(s:) Ch3ngetask(s) 0 Qther.saesa'o gj Prrvide a responseto thefol6owing: f., detailed and specific explanatiowratiornale of the requested change(s)to the tasks) and ! or the additional days added (if requested;; 2.l why this change was not included in theoriginal contract; and, 3.) describe the impact 0 this change is not processed ...._- ___ .,c _ , f,mna._.- frcmn the Dssigr Prcfessioral a d,or Ca tractor* 6 r__,ec. Prepared by: Date: Frost klarage' Name are Deb+3":m_r2 As«=ptarz of thzs Ctrars r rder she i cQrstit. a m ifo-=stern t r«try r kark ,, .,e, sartiax. zcale a 3 wr<r to s.,bj t tca a.ii t!^e same terms ai crxrdr: crr s as ct rra:re; in t:t a cc•^tract 1 vrork onde ird cafe at«cv=. a5 f,-6iy as f :he 5ama ao=re sta'e' ice, this a captarc e, The ardd;sstmer f. if any. tc t.hf C€ntrata s hsaii c _ s3 ituts a ft:11 s^d tin a! sett iemcn? cf a^-y ar=v ai§ claim s e>i the -Ca^tractor t t«'erv?r ,3 Cons a tiartll rrc=Aing claims for im.a z ar delay costs. Accepted by: Date:. Cont:raclort. rerdorlC_ __,,art D_sibnF'rof_ssrunaar NameofFirm. fpcyec-'appir_able; Approved by: Date: Des,gr F`rcfess v-a': s c °Lsme of Firm, t pro}cct applicatFe; Approved by: D3'e: Pr,x.. remeri Frofessoral 25 Construction Services Agreement: Revised 072118 (v6) 9 Page 4668 of 7162 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. Design Professional's Project No PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER And To Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 26 Construction Services Agreement: Revised 072118 (v6) G Page 4669 of 7162 RESPONSIBILITIES: OWNER: CONTRACTO The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on By: Design Professional Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on 20 OWNER By: Type Name and Title 27 Construction Services Agreement: Revised 072118 (v6) 9 Page 4670 of 7162 EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: Contractor: The following items have been secured by the for the Project known as PO No.: Date: and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner (attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As -Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14. Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: Company Name) Signature) Typed Name & Title) By Design Professional: Firm Name) Signature) Typed Name & Title) By Owner: Department Name) Signature) Name & Title) 28 Construction Services Agreement: Revised 072118 (v6) Page 4671 of 7162 EXHIBIT H: GENERAL TERMS AND CONDITIONS INTENT OF CONTRACT DOCUMENTS. 1. 1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and instal led as part of the Work, whether or not called for by the Contract Documents. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work -site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 29 Construction Services Agreement: Revised 072118 (v6) 9 Page 4672 of 7162 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub -Section 2.2 as the "Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3. 2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be 30 Construction Services Agreement: Revised 072118 (v6) Page 4673 of 7162 limited to the hours of 7 a.m. to 7 p.m., Monday through Saturday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.4 Contractor shall submit its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218. 735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 4.5 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re -submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is 31 Construction Services Agreement: Revised 072118 (v6) Page 4674 of 7162 stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent 50%) completion subject to the guidelines set forth in Florida Statute 255.078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub -subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub -subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non- payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 32 Construction Services Agreement: Revised 072118 (v6) e Page 4675 of 7162 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non -liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5. 3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off -set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 33 Construction Services Agreement: Revised 072118 (v6) Page 4676 of 7162 7. SUBMITTALS AND SUBSTITUTIONS. 7.1 Contractor shal I carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will 34 Construction Services Agreement: Revised 072118 (v6) 0 Page 4677 of 7162 record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub -Contractor's personnel; 8.1.4 The number of Contractor's and Sub -Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1.8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features 35 Construction Services Agreement: Revised 072118 (v6) C AO Page 4678 of 7162 e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The As -Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As -Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material -men, as well as coordinating its Work with all 36 Construction Services Agreement: Revised 072118 (v6) CAO Page 4679 of 7162 work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work 37 Construction Services Agreement: Revised 072118 (v6) e Page 4680 of 7162 Directive. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub -subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent 15%). All compensation due Contractor and any Subcontractor or sub -subcontractor for field and home office overhead is included in the markups noted above. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight 48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pendency of any Claim. 38 Construction Services Agreement: Revised 072118 (v6) CAO Page 4681 of 7162 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit B-3 to the Agreement. 39 Construction Services Agreement: Revised 072118 (v6) 9 Page 4682 of 7162 Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit B-3. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et sea. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet - based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: Commodity based procurement where no services are provided. Where the requirement for the affidavit is waived by the Board of County Commissioners Contractors / Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Contractor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Contractors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the Bidder/Contractor does not comply with providing both the acceptable E-Verify evidence and the executed affidavit the bidder's / Contractor's proposal may be deemed non- responsive. 40 Construction Services Agreement: Revised 072118 (v6) 0 Page 4683 of 7162 Additionally, Contractors shall require all subcontracted Contractors to use the E-Verify system for all purchases not covered under the "Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (E-Verify) program visit the following website: http://www.dhs. gov/E-Verify. It shall be the Contractor's responsibility to familiarize themselves with all rules and regulations governing this program. Contractor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et sea. and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2. 3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies when the Contractor is acquiring permits. Owner will not be obligated to pay for any permits obtained by Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 41 Construction Services Agreement: Revised 072118 (v6) Page 4684 of 7162 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default of the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s) within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials, equipment, supplies, and other items therefore or re -letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 42 Construction Services Agreement: Revised 072118 (v6) 0 Page 4685 of 7162 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below. 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager 43 Construction Services Agreement: Revised 072118 (v6) 9 Page 4686 of 7162 shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch -list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch -list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: 1) Receipt of Contractor's Final Application for Payment. 2) The Release and Affidavit in the form attached as Exhibit C. 3) Consent of surety to final payment. 4) Receipt of the final payment check list. 5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 44 Construction Services Agreement: Revised 072118 (v6) t i f Page 4687 of 7162 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re -inspection fees and costs; to the extent such re -inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight (8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shall as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non -defective Work. Contractor shall bear all direct, indirect and consequential 45 Construction Services Agreement: Revised 072118 (v6) Page 4688 of 7162 costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstructio n. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall 46 Construction Services Agreement: Revised 072118 (v6) Page 4689 of 7162 include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit A-1 is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.6, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight 48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 47 Construction Services Agreement: Revised 072118 (v6) Page 4690 of 7162 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, 48 Construction Services Agreement: Revised 072118 (v6) Page 4691 of 7162 Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5. 7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5. 9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend a pre -construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or 49 Construction Services Agreement: Revised 072118 (v6) 0 Page 4692 of 7162 Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre -construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right -of -Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.net/purchasing. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work ("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of 50 Construction Services Agreement: Revised 072118 (v6) 0 Page 4693 of 7162 the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self -performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub -subcontractor performing any portion of the Work, as well as maintain a log of all such licenses. All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of 51 Construction Services Agreement: Revised 072118 (v6) Page 4694 of 7162 Owner upon termination of Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third -party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its. sub - subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on -site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be caused by Owner or Design Professional or attributable to Owner or Design Professional and including claims based on breach of contract or negligence, shall be an extension of its contract time. 33.6.2 In the event of a change in the work, the Subcontractor's claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus no more than 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub -subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner, and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 52 Construction Services Agreement: Revised 072118 (v6) 0 Page 4695 of 7162 34.1.3 Shop Drawing Submittal/Approval Logs 34.1.4 Equipment Purchase/Delivery Logs 34.1.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 34.1.10 Equipment Costs 34.1.11 Cost Proposal Request 34.1.12 Payment Request Records 34.1.13 Meeting Minutes 34.1.14 Cost -Estimates 34.1.15 Bulletin Quotations 34.1.16 Lab Test Reports 34.1.17 Insurance Certificates and Bonds 34.1.18 Contract Changes 34.1.19 Permits 34.1.20 Material Purchase Delivery Logs 34.1.21 Technical Standards 34.1.22 Design Handbooks 34.1.23 As -Built" Marked Prints 34.1.24 Operating & Maintenance Instruction 34.1.25 Daily Progress Reports 34.1.26 Monthly Progress Reports 34.1.27 Correspondence Files 34.1.28 Transmittal Records 34.1.29 Inspection Reports 34.1.30 Punch Lists 34.1.31 PMIS Schedule and Updates 34.1.32 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the presentation requirements and format. Presentations may include, but not be limited to, the following information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shal I be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County 53 Construction Services Agreement: Revised 072118 (v6) 9 Page 4696 of 7162 under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e-mail DL-FMOPSCa.colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of $500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the Contractor is responsible for all costs. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A "project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid & Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing / will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48-hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials / petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 54 Construction Services Agreement: Revised 072118 (v6) Page 4697 of 7162 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision - making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision -making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 55 Construction Services Agreement: Revised 072118 (v6) Page 4698 of 7162 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS Attached hereto, following this page 56 Construction Services Agreement: Revised 072118 (v6) a Page 4699 of 7162 Exhibit I —Supplemental Terms and Conditions Minimum Qualifications of Bidders Solicitation 20-7769 South County Regional Water Treatment Plant (SCWTP) Reactor #4 Qualification of Bidders: Bidders/Contractors must show experience and successful completion of projects with the construction of Lime Softening Water Treatment Plants (including Clarifiers/Reactor Tanks), and water bearing concrete structures, or similar projects. A. Minimum qualification requirements for General Contractors shall include completion of at least 3 projects in the past ten (10) years, which meet the following criteria: 1. Minimum contract value of $1,500,000. 2. Water or wastewater treatment plant projects. The scope of work for these reference projects shall include either water and/or wastewater clarifiers (including mechanisms with rotating assemblies) in circular reinforced concrete water retaining structures of at the least the size indicated on the drawings. 3. Retrofit, rehabilitation, or improvements completed to an operating water or wastewater facility without unreasonable disruptions to service due to Contractor's actions or failure to act. 4. Work including water retaining structures, gravity and pressure piping systems, site work, structural, mechanical, electrical, and instrumentation work of similar type, size, and complexity. 5. Projects completed and operating to the satisfaction of Owner (to be verified by calling references). 6. Projects completed on time. 7. Projects completed within budget without unreasonable claims or excessive change orders. 8. Proposed project manager and superintendent shall personally have completed projects to meet all criteria listed above as well. B. Any subcontractors selected by Contractor shall have equivalent experience for the trade in which the work will be performed (exclusive of dollar value noted). BIDDERS TO PROVIDE EVIDENCE OF THE ABOVE ON FORM 5 — STATEMENT OF EXPERIENCE OF BIDDER AS FOUND IN THE SOLICITATION DOCUMENT USE ADDITIONAL COPIES OF FORM 5 IF NECESSARY Ow Page 4700 of 7162 ACoRI:> CERTIFICATE OF LIABILITY INSURANCE ATE (MMIDD/Y 7/01/2020YY) F THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 1-317-844-7759 CONTACT NAME: Sherri Abbett AssuredPartners Of Indiana, LLC PHONE FAX No. Ext: 317-595-7361 A/C No: AILADDRESS: sherri.abbett@assuredpartners.com10401N. Meridian #300 INSURERS AFFORDING COVERAGE NAIC # INSURERA:XL INS AMER INC 24554Indianapolis, IN 46290 INSURED INSURERB: STARR IND & LIAB CO 38318 Mitchell & Stark Construction Co., Inc. INSURER C:XL SPECIALTY INS CO 37885 INSURER D: NAUTILUS INS CO 17370 6001 Shirley Street INSURER E: AGCS MARINE INS CO 22837 INSURER F: Naples, FL 34109 COVERAGES CERTIFICATE NUMBER: 59706674 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSRLTR TYPE OF INSURANCE ADDL SUBR WV POLICY NUMBER POLICY EFF MM/DD/YYYY POLICY EXP MM/DD/YYYY LIMITS A X COMMERCIAL G ENERALLIABILITY X CGS740906408 03/01/ 20 03/01/21 EACH OCCURRENCE 1,000,000 CLAIMS -MADE FT]OCCUR DAMAGE To ENTED PREM SES (Ea occur ence) 300,000 MED EXP (Any one person) 10,000 PERSONAL & ADV INJURY 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE 2,000,000 PRO X LODPOLICYIF -JECT PRODUCTS - COMP/OP AGG 2,000, 000 EMPLOYEE BENEFIT 2,000, 000OTHER: A AUTOMOBILE LIABILITY X CAH740002709 03/01/20 03/01/21 COMBINED SINGLE LIMIT Ea accident 1,000, 000 BODILY INJURY (Per person) ANY AUTO OWNED SCHEDULED AUTOS ONLY AUTOSIX BODILY INJURY (Per accident) PROPERTY DAMAGE Per accidentXHIREDXNON -OWNEDAUTOSONLYAUTOSONLY B X UMBRELLA LIAB X OCCUR X 1000584931201 03/01/20 03/01/21 EACH OCCURRENCE 5,000,000 AGGREGATE 5,000,000EXCESSLIABCLAIMS -MADE DED I X RETENTION $ 0 C WORKERS COMPENSATIONEMPLOYERS' LIABILITY Y / N ANYPROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? Mandatory in NH) NIA CWG740002509 03/01/20 03/01/21 X STATUTE OEIIIANDE. L. EACH ACCIDENT 1,000,000 E. L. DISEASE - EA EMPLOYEE 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT 1,000,000 D CPL-PROFESSIONAL CPP201737414 03/01/20 03/01/21 OCC/AGG 5,000,000 E INSTALL -BUILDER'S RISK MZI93015110 03/01/20 03/01/21 2,500 DED/LIMIT 350,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Re: Project description is Bid No 20-7769 SWRWTP Reactor Tank # 4. Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County Included as an Additional Insured Under the Captioned Commercial General Liability and Auto Liability Policies on a Primary Non -Contributory Basis if and to the Extent Required by Written Contract. CERTIFICATE HOLDER CANCELLATION Collier County Board of County Commissioners 3295 Tamiami Trail E. Building C2 Naples, FL 34112 USA SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE 1988- 2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD SABBETT 59706674 Page 4701 of 7162 10401 N. Meridian St., Suite 300 Indianapolis, IN 46290 AssuredPartners Fax: 317-815-6036 or Fax 317-844-9910 of Indiana IF YOU ARE THE RECIPIENT OF THIS CERTIFICATE: ANY WORDING TO PROVIDE ADDITIONAL INSURED COVERAGE, PROVIDE COVERAGE ON A PRIMARY AND NON-CONTRIBUTORY BASIS, OR PROVIDE A WAIVER OF SUBROGATION APPLIES ONLY WHERE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT. CONTRACTUAL LIABILITY COVERAGE IS ONLY PROVIDED TO THE EXTENT SET FORTH IN THE POLICIES AND MAY NOT COVER ALL LIABILITY ASSUMED BY THE NAMED INSURED UNDER THE CONTRACT. IF YOU ARE THE REQUESTOR OF THIS CERTIFICATE OF INSURANCE: AssuredPartners of Indiana, LLC has, upon your request, issued the attached Certificate of Insurance. If you have not already done so, we highly recommend that you provide AssuredPartners of Indiana, LLC with a copy of the insurance and indemnification provisions of the contract pertaining to the Certificate of Insurance request so that we may properly ascertain whether the referenced insurance policies address the limits of insurance, terms and types of coverage required by the contract. While most Certificates of Insurance can be issued at no cost, the contract may require the purchase of additional insurance coverage that could be subject to an additional premium charge. In some instances, the coverage identified in the contract may be outside the underwriting guidelines of the insurance carrier and cannot be obtained. Any contract review performed by AssuredPartners of Indiana, LLC should not be construed as the rendering of legal advice or a legal opinion concerning any portion of the contract. AssuredPartners of Indiana, LLC has not endeavored to identify all potential liability issues that might arise under this contract. This review is provided for information purposes only and should not be relied upon by third parties. Any description of insurance coverage is subject to the terms, conditions, exclusions and other provisions of the policies and any applicable regulations, rating rules or plans. This Certificate of Insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD forms & Policy Cancellation Requirements Effective September 2009, ACORD revised the ACORD 25 Certificate of Insurance and the Acord 27 & 28 Evidence of Property forms, the major change being removal of the cancellation notice provision. Per our contract with ACORD, we are not able to alter pre-existing wording on the current form, nor are we able to complete a proprietary form you provide: Per Indiana House Enrolled Act 1322, effective July 1, 2013, Sec.13. (a) A person is not entitled to notice of: 1) cancellation of 2) non -renewal of; or 3) a material change in; a policy of property or casualty insurance unless the person has notice rights under the terms of the policy of property or casualty insurance or an endorsement to the policy. Violation of this statute is considered an unfair and deceptive act or practice under Indiana Law and if an agent is found to be in violation, they can possibly lose their license, and an insured or customer can possibly be fined. We appreciate your understanding of the legal restrictions on our ability to fully comply with your request. Page 4702 of 7162 SUPPLEMENT TO CERTIFICATE OF INSURANCE o/ DATE ol/aozo NAME OF INSURED: Mitchell & Stark Construction Co., Inc. SUPP (10/ 00) Page 4703 of 7162 COLLIER COUNTY For the Acquisition of Goods and Services Funded By Federal/State Grant Programs Method of Procurement Decision Form PURPOSE: To best determine and document the method of procurement suitable. Classify the procurement situation by ensuring the appropriate conditions below. All elements must apply to use that method. CHECK ONE: Small Purchase Amount <$50,000 (Federal threshold is <$100, 000 —County policy more restrictive. Follow Local Purchasing Policy). Multiple sources available Two or more quotes written/verbal quotes above Micro -Purchase Threshold ($3,000). Grantor agencies require an adequate number of sources for competition under $150,000 - local policy defines the number of adequate sources below.) RANGE INSTRUMENT COMPETITION 0-3,000 Requisition P.O. 1 Verbal Quote 3 000.01-10 000 Requisition P.O. 3 Verbal Quotes 10,000.01-50,000 Requisition P.O. 3 Written Quotes Competitive Procurement Amount >$50,000 (Federal threshold is <$150, 000-- County policy more restrictive. A BCC waiver would be required for informal procurement between $50,000 - $150, 000) Multiple sources available Sealed Bid (IFB) Complete & adequate specs Two or more responsible bidders willing to compete Selection can be made on basis of price Procurement suitable for firm, fixed price No discussion with bidders needed after receipt of offers Competitive Proposals (RFP) Competition specifications not feasible Bidder input needed for specification Two or more responsible bidders willing to compete Discussion needed with bidders after receipt of proposals, prior to award Fixed price can be set after discussion No Cost Plus a Percentage of Cost Contracts (IE—time and material must have ceiling) Sole Source/Noncompetitive (if selected, complete Sole Source Documentation - includes change orders) REQUSITIONED BY: Tami Scott- Project Manager - Bayshore CRA June 22, 2020 est. FY14 v, 3 Page 4704 of 7162 abbott_a Digitally signed by abbott_a DN: E=Alicia.Abbott@colliercountyfl.gov, CN=abbott_a, OU=General, OU=PPM User Accounts, OU=PUD Planning and Project Management, OU=PUD, OU=Divisions, DC=bcc, DC=colliergov, DC=net Date: 2021.10.12 08:57:12-04'00' Digitally signed by Christopher T. Reinbold Contact Info: Carollo Engineers, Inc. Date: 2021.10.12 08:43:56-04'00' BullertBenjamin Digitally signed by BullertBenjamin DN: E=Benjamin.Bullert@colliercountyfl.gov, CN=BullertBenjamin, OU=General, OU=PPM User Accounts, OU=PUD Planning and Project Management, OU=PUD, OU=Divisions, DC=bcc, DC=colliergov, DC=net Date: 2021.10.12 11:40:19-04'00' Page 4705 of 7162 ChmelikTom Digitally signed by ChmelikTom Date: 2021.10.12 14:26:22 -04'00' Steve Messner Digitally signed by Steve Messner Date: 2021.10.13 06:38:48 -04'00' Joseph Bellone Digitally signed by Joseph Bellone Date: 2021.10.13 08:34:20 -04'00' Schneeberg erSara Digitally signed by SchneebergerSara Date: 2021.10.20 13:36:31 -04'00' Page 4706 of 7162 Page 4707 of 7162 Collier County Planning & Project Management Department WORK DIRECTIVE CHANGE CHANGE #5 DATE OF ISSUANCE: January 29, 2021 (revised) Work Order/Purchase Order #: 4500204556 Contract No. 20-7769 PROJECT#: 70135.2 OWNER: Collier County Board of County Commissioners PROJECT: SCRWTP Reactor Tank 4 CONTRACTOR: Mitchell & Stark Construction, Inc. You are directed to proceed promptly with the following change(s): DESCRIPTION: Provide new piping for the effluent of Reactors 2 and 3 and modify the effluent piping associated with Reactor 4. PURPOSE OF WORK DIRECTIVE CHANGE: Previously, County forces excavated and took field measurements of the effluent piping of existing Reactor 2. It was found to differ from record drawing information. Due to the hydraulic limitations of Reactor 2 to treat the rated flow, the County desires the effluent piping be replaced with new effluent piping. In addition, the County desires the effluent piping of Reactor 3 and the overall 42-inch reactors effluent header to be replaced. It is the intent of this Work Directive Change to provide replacement of Reactors 2 & 3 effluent piping, modify the effluent piping of Reactor 4, as well as abandon in place the 42-inch header. The attached drawings represent the schematic design for these changes. This information is being transmitted for the Contractor to begin material procurement to establish costs and lead time. Consultant is performing final design which will add concrete pipe supports for Reactors 3 and 4 effluent piping, steel stanchion type pipe support for Reactor 3 effluent piping, and the associated structural design information for the recarbonation basin wall penetrations. Drawings 00C02, 00C03, and 00C03A are attached with changes clouded. Typical Details P602 and P624 are also attached. This change was not included in the original work order as it was not anticipated that a decision would be made to modify the Reactor 2 and 3 effluent piping as part of this project. As a result of the age of the existing piping, identified scaling, and known hydraulic performance challenges, the County desires to proceed with this piping change. If this change is not processed, the engineer will not be able to provide the necessary information required to provide clear direction to the contractor, to correct the existing piping issues, and the contractor proceed with procuring and installing the revised piping design. There exists an opportunity for the contractor to install this modified piping concurrent with the existing project with minimal change to the sequencing and reduce impacts to the water treatment process. Not performing the piping improvements would result in not addressing known hydraulic performance challenges and replace existing infrastructure that is approaching 40 years old. Page 4708 of 7162 If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order based thereon will involve one or more of the following methods of determining the effect of the changes(s). Method of determining change in Contract Price: Method of determining change in Contract Times: Unit Prices Contractor’s records Lump Sum Engineer’s record Other: TIME & MATERIALS Other County Inspector observations and Contractor field records Use of Allowance Funds: to be determined Estimated increase in Contract Price: $0 Estimated change in Work Order Time: Increase or decrease by TBD calendar days. RECOMMENDED BY (Engineer of Record): _____________________________Date: 01-29-21 REVIEWED BY (Owner’s Representative): _________________________________Date: ________ Alicia Abbott, EI., PMP, Project Manager AUTHORIZED BY (Owner’s Representative): _________________________________Date: ________ Benjamin Bullert, P.E. – Principal Project Manager Page 4709 of 7162 Collier County SCRWTP Reactor Tank #4 Change Order #4 Cost Summary Direct Labor 7% Other Direct $53,650.00 and Material and Activity Unit Quantity Materials Equipment w/ Tax Subcontract Markup Unit Price Total 0.00 0.00 0.00 Work Directive #5 0.00 0.00 0.00 Materials 0.00 0.00 0.00 0.00 0.00 0.00 Subcontracts 0.00 0.00 0.00 Painting ls 1.00 0.00 10000.00 1000.00 11000.00 11000.00 Ferguson Misc. Hardware & PVC ls 1.00 5000.00 5350.00 500.00 5850.00 5850.00 0.00 0.00 0.00 M&S Labor 0.00 0.00 0.00 John Deere 544 Loader hr 40.00 95.00 0.00 95.00 3800.00 John Deere 120 Excavator hr 40.00 130.00 0.00 130.00 5200.00 Plate Compactor day 0.00 70.00 0.00 70.00 0.00 Project Manager hr 20.00 90.00 0.00 90.00 1800.00 Field Supervisor hr 80.00 55.00 0.00 55.00 4400.00 Operator/Foreman hr 120.00 50.00 0.00 50.00 6000.00 Pipe Layer/Semi-Skilled hr 120.00 40.00 0.00 40.00 4800.00 Laborer/Unskilled hr 60.00 30.00 0.00 30.00 1800.00 Pickup w/Tools hr 150.00 60.00 0.00 60.00 9000.00 0.00 0.00 0.00 Subtotal $53,650.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 53650.00 53,650.00 For estimating purposes only. Actual time and materials may vary based on conditions encountered Page 4710 of 7162 Collier County Planning & Project Management Department WORK DIRECTIVE CHANGE CHANGE #6 DATE OF ISSUANCE: February 12, 2021 Work Order/Purchase Order #: 4500204556 Contract No. 20-7769 PROJECT#: 70135.2 OWNER: Collier County Board of County Commissioners PROJECT: SCRWTP Reactor Tank 4 CONTRACTOR: Mitchell & Stark Construction, Inc. You are directed to proceed promptly with the following change(s): DESCRIPTION: Provide new 4-inch ductile iron water main piping in lieu of 2-inch schedule 80 PVC water main piping to supply the new Reactor 4 spray system, hose bibbs, and hydraulic actuators. PURPOSE OF WORK DIRECTIVE CHANGE: Previously, the Contractor performed a repair to an existing 6- inch water main tee near the north west area of existing Reactor 3. The tee fitting was found to have a plug on the line end of the tee which is presumed to have been placed for future extension. A 2-inch water main was shown being installed to serve the new Reactor 4 water supply spray system. During shop drawing review for the new Reactor 4, the manufacturer recommended the size of water main be increased to 4-inch to accommodate the necessary water supply flow rate. The attached drawing (00C02) and pipe schedule (from Section 40_05_00.01) identify these changes. Water main piping was included in the original work order but the spray system sizing design was not completed until the manufacturer prepared the shop drawings. Initial sizing estimates provided during the design period were lower. As a result of ensuring the new spray system operates per manufacturer recommendations, the County desires to proceed with this piping change. If this change is not processed, then softening system performance may be impacted. Not performing the piping installation would result in not providing sufficient water to the new Reactor spray system. If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order based thereon will involve one or more of the following methods of determining the effect of the changes(s). Method of determining change in Contract Price: Method of determining change in Contract Times: Unit Prices Contractor’s records Lump Sum Engineer’s record Other: TIME & MATERIALS Other County Inspector observations and Contractor field records Page 4711 of 7162 Use of Allowance Funds: to be determined Estimated increase in Contract Price: $0 Estimated change in Work Order Time: Increase or decrease by TBD calendar days. RECOMMENDED BY (Engineer of Record): _____________________________Date: 02-12-21 REVIEWED BY (Owner’s Representative): _________________________________Date: ________ Alicia Abbott, EI., PMP, Project Manager AUTHORIZED BY (Owner’s Representative): _________________________________Date: ________ Benjamin Bullert, P.E. – Principal Project Manager Page 4712 of 7162 Collier County SCRWTP Reactor Tank #4 Change Order #4 Cost Summary Direct Labor 7% Other Direct $21,911.13 and Material and Activity Unit Quantity Materials Equipment w/ Tax Subcontract Markup Unit Price Total 0.00 0.00 0.00 Work Directive #6 0.00 0.00 0.00 Materials 0.00 0.00 0.00 Ferguson - Additional 6" & 4" Materia ls 1.00 7312.33 7824.19 731.23 8555.43 8555.43 Ferguson - Credit for 2" Material ls -1.00 985.32 1054.29 1054.29 -1054.29 0.00 0.00 0.00 M&S Labor 0.00 0.00 0.00 John Deere 544 Loader hr 24.00 95.00 0.00 95.00 2280.00 John Deere 120 Excavator hr 24.00 130.00 0.00 130.00 3120.00 Plate Compactor day 1.00 70.00 0.00 70.00 70.00 Project Manager hr 2.00 90.00 0.00 90.00 180.00 Field Supervisor hr 24.00 55.00 0.00 55.00 1320.00 Operator/Foreman hr 24.00 50.00 0.00 50.00 1200.00 Pipe Layer/Semi-Skilled hr 48.00 40.00 0.00 40.00 1920.00 Laborer/Unskilled hr 48.00 30.00 0.00 30.00 1440.00 Pickup w/Tools hr 48.00 60.00 0.00 60.00 2880.00 0.00 0.00 0.00 Subtotal $21,911.13 0.00 0.00 0.00 0.00 0.00 0.00 21911.13 21,911.13 For estimating purposes only. Actual time and materials may vary based on conditions encountered Page 4713 of 7162 Collier County Planning & Project Management Department WORK DIRECTIVE CHANGE CHANGE #9 DATE OF ISSUANCE: March 18, 20211 Work Order/Purchase Order #: 4500204556 Contract No. 20-7769 PROJECT#: 70135.2 OWNER: Collier County Board of County Commissioners PROJECT: SCRWTP Reactor Tank 4 CONTRACTOR: Mitchell & Stark Construction, Inc. You are directed to proceed promptly with the following change(s): DESCRIPTION: Provide bell restraints for fittings on reactor 2 drain piping. PURPOSE OF WORK DIRECTIVE CHANGE: During installation of the drain piping from reactor 2, the Contractor encountered multiple bell joints in series. Due to adjacent conflicts (duct bank, effluent piping, and slope needed to drain) the deflection of the existing piping exceeds the manufacturer’s allowable for one joint. The Contractor is using restrained joint piping utilizing Flex-Ring, which requires factory welding a restraint ring to the plain end. In order to accommodate the multiple bell joints in series, the Contractor can field cut the plain end, which will remove the restraining device. In order to provide restraint, external bell harnesses are proposed. It is the intention of this Work Directive Change to authorize the Contractor to furnish and install three external bell harnesses. The model proposed, which is acceptable, is Sigma PV-LOK Model PWP for ductile irone pipe. Additional labor costs would only be considered if outside the scope of Paragraph 3.01.A.1 of Section 40 05 00.01. The Contractor has already excavated the piping in this area as it relates to the performance of the work associated with the drain line. Having the Contractor provide the bell harnesses will allow the use of piping already onsite and for the work to be completed (the harnesses are a locally stocked commodity). The alternative would be to custom order the short spools of pipe with factory welded Flex-Ring which would increase lead time (greater than 4 weeks) and would require re-excavation as it is not safe for an excavation to remain open for multiple weeks. It is anticipated to cost less using the bell harnesses than custom ordering piping. If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change Order based thereon will involve one or more of the following methods of determining the effect of the changes(s). Method of determining change in Contract Price: Method of determining change in Contract Times: Unit Prices Contractor’s records Lump Sum Engineer’s record Other: TIME & MATERIALS Other County Inspector observations and Contractor field records Use of Allowance Funds: estimated $2,500 Estimated increase in Contract Price: $0.00 Estimated change in Work Order Time: 0 Increase or decrease by 0 calendar days. RECOMMENDED BY (Engineer of Record): _____________________________Date: ____________ 3/18/21 Page 4714 of 7162 REVIEWED BY (Owner’s Representative): _________________________________Date: ________ Alicia Abbott, EI., PMP, Project Manager AUTHORIZED BY (Owner’s Representative): _________________________________Date: ________ Benjamin Bullert, P.E. – Principal Project Manager Page 4715 of 7162 Collier County SCRWTP Reactor Tank #4 Change Order #4 Cost Summary Direct Labor 7% Other Direct $4,714.00 and Material and Activity Unit Quantity Materials Equipment w/ Tax Subcontract Markup Unit Price Total 0.00 0.00 0.00 Work Directive #9 0.00 0.00 0.00 Materials 0.00 0.00 0.00 Ferguson - Bell Restraints ls 1.00 200.00 214.00 20.00 234.00 234.00 0.00 0.00 0.00 M&S Labor 0.00 0.00 0.00 John Deere 544 Loader hr 8.00 95.00 0.00 95.00 760.00 John Deere 120 Excavator hr 8.00 130.00 0.00 130.00 1040.00 Field Supervisor hr 8.00 55.00 0.00 55.00 440.00 Operator/Foreman hr 8.00 50.00 0.00 50.00 400.00 Pipe Layer/Semi-Skilled hr 16.00 40.00 0.00 40.00 640.00 Laborer/Unskilled hr 8.00 30.00 0.00 30.00 240.00 Pickup w/Tools hr 16.00 60.00 0.00 60.00 960.00 0.00 0.00 0.00 Subtotal $4,714.00 0.00 0.00 0.00 0.00 0.00 0.00 4714.00 4,714.00 For estimating purposes only. Actual time and materials may vary based on conditions encountered Page 4716 of 7162 Page 4717 of 7162 Page 4718 of 7162 Collier County SCRWTP Reactor Tank #4 Change Order #4 Cost Summary Direct Labor 7% Other Direct $5,065.00 and Material and Activity Unit Quantity Materials Equipment w/ Tax Subcontract Markup Unit Price Total 0.00 0.00 0.00 Work Directive #10 0.00 0.00 0.00 Materials 0.00 0.00 0.00 Ferguson - 8" Sleeve & Megalugs ls 1.00 500.00 535.00 50.00 585.00 585.00 0.00 0.00 0.00 M&S Labor 0.00 0.00 0.00 John Deere 544 Loader hr 8.00 95.00 0.00 95.00 760.00 John Deere 120 Excavator hr 8.00 130.00 0.00 130.00 1040.00 Field Supervisor hr 8.00 55.00 0.00 55.00 440.00 Operator/Foreman hr 8.00 50.00 0.00 50.00 400.00 Pipe Layer/Semi-Skilled hr 16.00 40.00 0.00 40.00 640.00 Laborer/Unskilled hr 8.00 30.00 0.00 30.00 240.00 Pickup w/Tools hr 16.00 60.00 0.00 60.00 960.00 0.00 0.00 0.00 Subtotal $5,065.00 0.00 0.00 0.00 0.00 0.00 0.00 5065.00 5,065.00 For estimating purposes only. Actual time and materials may vary based on conditions encountered Page 4719 of 7162 Page 4720 of 7162 Page 4721 of 7162 Page 4722 of 7162 Page 4723 of 7162 Page 4724 of 7162 Page 4725 of 7162 Page 4726 of 7162 Page 4727 of 7162 Page 4728 of 7162 Page 4729 of 7162 Page 4730 of 7162 Page 4731 of 7162 Page 4732 of 7162 Page 4733 of 7162 Page 4734 of 7162 Page 4735 of 7162 Page 4736 of 7162 Page 4737 of 7162 Page 4738 of 7162 Page 4739 of 7162 Page 4740 of 7162 Page 4741 of 7162 Page 4742 of 7162 Page 4743 of 7162 Page 4744 of 7162 Page 4745 of 7162 Page 4746 of 7162 Page 4747 of 7162 Page 4748 of 7162 Collier County SCRWTP Reactor Tank #4 Change Order #6 Cost Summary Direct Labor 7% Other Direct $8,891.33 and Material and Activity Unit Quantity Materials Equipment w/ Tax Subcontract Markup Unit Price Total 0.00 0.00 0.00 Work Directive #7 0.00 0.00 0.00 See attached credit and backup -1.00 0.00 5287.65 -5287.65 0.00 0.00 0.00 Work Directive #16 - All Work Completed 0.00 0.00 0.00 See attached cost summary and backup 1.00 0.00 14178.98 14178.98 0.00 0.00 0.00 0.00 0.00 0.00 8891.33 8,891.33 For estimating purposes only. Actual time and materials may vary based on conditions encountered Page 4749 of 7162 Page 4750 of 7162 Page 4751 of 7162 Page 4752 of 7162 Page 4753 of 7162 Page 4754 of 7162 Page 4755 of 7162 Page 4756 of 7162 Page 4757 of 7162 Page 4758 of 7162 Page 4759 of 7162 Page 4760 of 7162 Page 4761 of 7162 Page 4762 of 7162 Page 4763 of 7162 TBD This contract is currently under a stop work with one day remaining. Page 4764 of 7162 Page 4765 of 7162 Page 4766 of 7162 Page 4767 of 7162 Page 4768 of 7162 Page 4769 of 7162 Page 4770 of 7162 Page 4771 of 7162 Page 4772 of 7162 Page 4773 of 7162 Page 4774 of 7162 Page 4775 of 7162 Page 4776 of 7162 Page 4777 of 7162 Page 4778 of 7162 Page 4779 of 7162 Page 4780 of 7162 Page 4781 of 7162 Page 4782 of 7162 Page 4783 of 7162 Page 4784 of 7162 Page 4785 of 7162 Page 4786 of 7162 Page 4787 of 7162 Page 4788 of 7162 Page 4789 of 7162 Page 4790 of 7162 Page 4791 of 7162 Page 4792 of 7162 Page 4793 of 7162 Page 4794 of 7162 Page 4795 of 7162 Page 4796 of 7162 Page 4797 of 7162 Page 4798 of 7162 Page 4799 of 7162 Page 4800 of 7162 Page 4801 of 7162 Page 4802 of 7162 Page 4803 of 7162 Page 4804 of 7162 Page 4805 of 7162 Page 4806 of 7162 Page 4807 of 7162 Page 4808 of 7162 Page 4809 of 7162 Page 4810 of 7162 Page 4811 of 7162 Page 4812 of 7162 Page 4813 of 7162 Page 4814 of 7162 Page 4815 of 7162 Page 4816 of 7162 Page 4817 of 7162 Page 4818 of 7162 Page 4819 of 7162 Page 4820 of 7162 Page 4821 of 7162 Page 4822 of 7162 Page 4823 of 7162 Page 4824 of 7162 Page 4825 of 7162 Page 4826 of 7162 Page 4827 of 7162 Page 4828 of 7162 Page 4829 of 7162 Page 4830 of 7162 Page 4831 of 7162 Page 4832 of 7162 Page 4833 of 7162 Page 4834 of 7162 Page 4835 of 7162 Page 4836 of 7162 Page 4837 of 7162 Page 4838 of 7162 Page 4839 of 7162 Page 4840 of 7162 Page 4841 of 7162 Page 4842 of 7162 Page 4843 of 7162 Page 4844 of 7162 Page 4845 of 7162 Page 4846 of 7162 Page 4847 of 7162 Page 4848 of 7162 Page 4849 of 7162 Page 4850 of 7162 Page 4851 of 7162 Page 4852 of 7162 Page 4853 of 7162 Page 4854 of 7162 Page 4855 of 7162 Page 4856 of 7162 Page 4857 of 7162 Page 4858 of 7162 Page 4859 of 7162 Page 4860 of 7162 Page 4861 of 7162 Page 4862 of 7162 Page 4863 of 7162 Page 4864 of 7162 Page 4865 of 7162 Page 4866 of 7162 Page 4867 of 7162 Page 4868 of 7162 Page 4869 of 7162 Page 4870 of 7162 Page 4871 of 7162 Page 4872 of 7162 Page 4873 of 7162 Page 4874 of 7162 Page 4875 of 7162 Page 4876 of 7162 Page 4877 of 7162 Page 4878 of 7162 Page 4879 of 7162 Page 4880 of 7162 Page 4881 of 7162 Page 4882 of 7162 Page 4883 of 7162 Page 4884 of 7162 Page 4885 of 7162 Page 4886 of 7162 Page 4887 of 7162 Page 4888 of 7162 Page 4889 of 7162 Page 4890 of 7162 Page 4891 of 7162 Page 4892 of 7162 Page 4893 of 7162 Page 4894 of 7162 Page 4895 of 7162 Page 4896 of 7162 Page 4897 of 7162 Page 4898 of 7162 Page 4899 of 7162 Page 4900 of 7162 Page 4901 of 7162 Page 4902 of 7162 Page 4903 of 7162 Page 4904 of 7162 Page 4905 of 7162 Page 4906 of 7162 Page 4907 of 7162 Page 4908 of 7162 Page 4909 of 7162 Page 4910 of 7162 Page 4911 of 7162 Page 4912 of 7162 Page 4913 of 7162 Page 4914 of 7162 Page 4915 of 7162 Page 4916 of 7162 Page 4917 of 7162 Page 4918 of 7162 Page 4919 of 7162 Page 4920 of 7162 Page 4921 of 7162 Page 4922 of 7162 Page 4923 of 7162 Page 4924 of 7162 Page 4925 of 7162 Page 4926 of 7162 Page 4927 of 7162 Page 4928 of 7162 Page 4929 of 7162 Page 4930 of 7162 Page 4931 of 7162 Page 4932 of 7162 Page 4933 of 7162 Page 4934 of 7162 Page 4935 of 7162 Page 4936 of 7162 Page 4937 of 7162 Page 4938 of 7162 Page 4939 of 7162 Page 4940 of 7162 Page 4941 of 7162 Page 4942 of 7162 101 East Kennedy Boulevard, Suite 700 Tampa, Florida 33602 P 813-888-9572 carollo.com pw://FL/Collier County/201636-200000/02 Project Information/01 Correspondence/McLeanM_2023-0911 September 11, 2023 Matthew McLean, P.E. Division Director Collier County - Engineering & Project Management Division 3339 Tamiami Trail East, Suite 303 Naples, FL 34112 Subject: Collier County - South County Regional WTP Project (Construction Agreement No 20-7769) Work Directives No. 05 and No. 12 Carollo Evaluation Dear Mr. McLean: As Carollo's Area Manager-Construction Manager, I was tasked with creating opinions of probable construction cost (OPCC) estimates for two work directives related to the subject project. These were Work Directive No. 05, which involved modifications to the Reactors 2, 3, and 4 effluent piping, and Work Directive No.12, which focused on concrete modifications for Reactor 4. The Carollo CM group carefully reviewed the documents provided by the contractor, Mitchell & Stark Construction Co., Inc., as well as all the supporting information. Once we had completed our review, we developed two OPCC estimates and sent them to the County and the Contractor for their review on August 31, 2023. Following this, Carollo had a meeting with Collier County to discuss the OPCC estimates. Based on the feedback received, Carollo updated the estimates as a result of the meeting. Enclosed with this letter are the two OPCC estimates, generated by Carollo Engineers, Inc.: ▪ Collier County South County - WDC 12 Carollo Engineers OPCC Estimate ($146,573). ▪ Collier County South County - WDC 05 Carollo Engineers OPCC Estimate ($262,753). Should you require any further clarification or have any questions about the contents of this document, please do not hesitate to contact me. Sincerely, CAROLLO ENGINEERS, INC. Gerardo Torres, DBIA Principal Construction Manager cc: Chris Reinbold, Carollo Bob Cushing, Carollo Page 4943 of 7162 8/31/2023 Discipline Items Unit Cost UM Quantity Cost Superintendent/Foreman $60 MH 70 $4,200 Supervision Vehicle - Pickup and Tools $60 MH 70 $4,200 $8,400 Pipe Support (Material) $1,500 EA 2 $3,000 Pipe Support (Installation) - Operator / Laborer $150 MH 8 $1,200 Pipe Support Equipment - Forklift Operated $150 HR 4 $600 $4,800 Fillet / Manufacturer Support Pedestals Formwork (Material)$10 SF 800 $8,000 Formwork (Placement/Removal) - Laborer $70 MH 400 $28,000 Formwork (Placement/Removal) - Keyway Adjustment $70 MH 64 $4,480 Reinforcing Steel (Material Original Design) $2,000 TN 0.8 $1,600 Reinforcing Steel (Placement Original Design) $2,000 TN 0.8 $1,600 Reinforcing Steel (Removal Original Design) $2,000 TN 0.8 $1,600 Reinforcing Steel (Material) $2,000 TN 2.25 $4,500 Reinforcing Steel (Placement) $2,000 TN 2.25 $4,500 Concrete Fillet @ 7% waste (Material)$200 CY 120 $23,968 Structural Concrete Pump Truck $200 HR 12 $2,400 Concrete Fillet Placement $70 MH 120 $8,389 Concrete Fillet Finishing $70 MH 34 $2,345 Pipe Support Equipment - Forklift Operated $150 HR 8 $1,200 Concrete Pipe Supports Support Formwork (Material) $10 SF 60 $600 Support Formwork (Placement/Removal) - Laborer $70 MH 16 $1,120 Reinforcing Steel (Material) $2,000 TN 0.15 $300 Reinforcing Steel (Placement) $2,000 TN 0.15 $300 Concrete Supports @ 7% waste (Material)$170 CY 1 $155 Concrete Placement $70 MH 4 $280 Misc. Tools and Supplies $1,000 LS 1 $1,000 Crane Support $10,702 LS 1 $10,702 $107,038 $120,239 $4,208 $3,008 $127,455 $19,118 $146,573 Collier County - South County Regional WTP - Reactor 4 Mods - OPCC Scope of Work: Work Directive 12: Concrete Fillet, Pedestals, and Pipe Supports Supervision Subtotal Mechanical Supervision Opinion of Probable Construction Cost (OPCC) Mechanical Subtotal Structural Subtotal Total Direct Cost Subcontractor Bond and Insurance Sales Tax (7%) Subcontractor Total Contractor Overhead and Profit (15%) Page 4944 of 7162 8/31/2023 Discipline Items Unit Cost UM Quantity Cost Project Supervision $60 MH 120 $7,200 Supervision - Trucks / Tools $60 MH 120 $7,200 $14,400 Excavate / Existing Expose 42" (Labor) $50 MH 72 $3,600 Excavate Existing 42" Pipe 42" (Equipment) $150 MH 24 $3,600 Grout fill existing 42" (Labor) $45 MH 48 $2,160 Pipe grout fill material $150 CY 48 $7,200 $16,560 Install Bulkhead inside existing Recarbonation Basin $45 HR 48 $2,160 Bulkhead Material $5,000 LS 1 $5,000 Core drill existing tank $3,400 EA 3 $10,200 Install / Grout pipe link-seal $45 MH 24 $1,080 Install Above Grade Pipe, fittings, valves, supports - Pipe Layer $45 MH 336 $15,120 Equipment - Pipe Installation (Operated Rate) $150 HR 112 $16,800 Crane support for installation $175 HR 88 $15,400 Install 42" Pipe plug for final tie-in $45 HR 16 $720 Final Tie-in at Reactor $45 HR 144 $6,480 Standby Pumps During Shut down $1,040 DA 3 $3,120 Above Ground Pipe Painting $21,389 LS 1 $21,389 Pipe accessories & Misc. Material $19,023 LS 1 $19,023 $116,492 Concrete Pipe Supports Excavate / Backfill Pipe Support (Equipment) Operated $205 HR 54 $11,070 ABC Stone at pipe support $50 TN 12 $600 Reinforcing Steel - Supports (Supply) $2,000 TN 2.4 $4,800 Reinforcing Steel - Supports (Placement) $2,000 TN 2.4 $4,800 Install / Remove Formwork $70 MH 288 $20,125 Concrete pipe supports (Concrete Material) $170 CY 19 $3,230 Pour Concrete pipe supports (Labor) $70 MH 48 $3,325 Concrete Pump Truck $200 HR 16 $3,200 Pour Concrete Collar @ Existing Tank Excavate Backfill to bottom of Pipe Collar $70 HR 32 $2,240 Excavation / Backfill Pipe Collar (Equipment) Operated $205 HR 8 $1,640 Prep Existing Tank Surface $70 MH 4 $280 Drill & Dowel Existing Tank Walls $70 MH 24 $1,680 Reinforcing Steel (Supply) $2,000 TN 1 $2,000 Reinforcing Steel (Placement) $2,000 TN 1 $2,000 Install / Remove Formwork $70 MH 70 $4,900 Concrete (Material)$140 CY 8 $1,120 Concrete Pump Truck $200 HR 4 $800 Concrete Placement / Curing $70 MH 24 $1,680 $69,490 $216,942 $7,593 $3,946 $228,481 $34,272 $262,753 Collier County - South County Regional WTP - Reactors Mods - OPCC Scope of Work: Work Directive 5: New Effluent Piping for Reactors 2, 3, and 4. (Pay Application Item 3.11) Supervision Subtotal Site/Civil Site / Civil Subtotal Structural Supervision Opinion of Probable Construction Cost (OPCC) Structural Subtotal Total Direct Cost Subcontractor Bond and Insurance Sales Tax (7%) Subcontractor Total Contractor Overhead and Profit (15%) Mechanical Subtotal Mechanical Page 4945 of 7162 Page 4946 of 7162 Page 4947 of 7162 Page 4948 of 7162 Page 4949 of 7162 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER’S Project No 70135 Design Professional’s Project No. 11290A.10 PROJECT: 20-7769 South County Regional Water Treatment Plant (SCRWTP) Reactor Tank #4 CONTRACTOR: Mitchell & Stark Construction Co. Inc. Contract For SCRWTP Reactor Tank #4 Contract Date July 1, 2020 This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: Complete project. To Alicia Abbott E.I., PMP, Project Manager II, Public Utilities Engineering and Project Management Division OWNER And To Michael P. Westhafer, P.E., Vice President, Mitchell & Stark Construction Co. Inc. Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: November 10, 2023 DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within 30 days of the above date of Substantial Completion. Page 4950 of 7162 The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: RESPONSIBILITIES: OWNER: All of the above. CONTRACTOR Complete Punchlist The following documents are attached to and made a part of this Certificate: Substantial completion punchlist. This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR’S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on November 10, 2023 Design Professional By: C.T. Reinbold, P.E. – Project Manager Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on November 10, 2023 CONTRACTOR By: Michael P. Westhafer, P.E., Vice President Type Name and Title OWNER accepts this Certificate of Substantial Completion on November 10, 2023 OWNER By: Alicia Abbott E.I., PMP, Project Manager II Type Name and Title Page 4951 of 7162 301 NORTH CATTLEMEN ROAD, SUITE 302 ▪ SARASOTA, FLORIDA 34232 ▪ P 941-371-9832 pw://Carollo/Client/FL/Collier County/11290A10/Disciplines/Construction/Correspondence/SubstantialCompletionPunchlist.docx FINAL / 1 PROJECT MEMORANDUM COLLIER COUNTY SCRWTP Reactor 4 Project No.: 11290A.10 Date: Draft issued September 22, 2023, Final issued November 10, 2023 Prepared By: Chris Reinbold Punchlist Walkthrough Attendees: Alicia Abbott, Bob Cushing, Dustin Grossenbaugh, Randy Lewis, Matt McLean, Gary Newcomer, Josh Peterson, Brandon Tripp Subject: Substantial Completion Punchlist A substantial completion punchlist walkthrough was held on September 22, 2023 beginning at approximately 8:30 am. The following items were noted. General Comments 1. Provide permanent pipe labeling. Recarbonation Basin 2. Remove PVC standpipe at reactor 3 effluent that was used for a survey point. 3. Clean rust on reactor 3 effluent piping. 4. Tighten nuts on thrust rod restraint for reactor 3 effluent piping at basin wall. Reactor 4 5. Touch-up reactor 4 effluent pipe coating scrapes. 6. Clean rust stains on reactor 4 effluent piping at bolts. 7. Correct leaking effluent pipe link seal. 8. Check torque on mega-lug bolt which has head not fully snapped off. 9. Paint exterior of reactor 4. 10. Repair leaks in reactor 4, several tie holes are damp. 11. Install fence and gate around stairs as indicated on civil drawing. 12. Paint nuts on reactor 4 influent piping. 13. Correct leaking influent pipe link seal. 14. Label conduits and spares at stub ups near f-valve locations. 15. Correct leaking link seal for overflow piping. 16. Correct sludge blowdown pipe link seals that are leaking. 17. Provide label for f-valve control panel. 18. Touch up scrape on sludge blowdown piping. 19. Remove red painter tape from conduits. 20. Remove concrete spatter from conduits. Page 4952 of 7162 PROJECT MEMORANDUM FINAL / 2 21. Touch up coat nut on f-valve. 22. Cut off lift hooks from concrete pile used as control panel support. 23. Clean up/remove excess coating buckets from site. 24. Turn over touch-up coating from each coating system and color used on project per coating specification. 25. Correct leaking solenoid valve and spray header f-valve. 26. Provide label for small valve control panel at top walkway. 27. Touchup coat mixer housing where rusting. 28. Replace desiccant on mixer oil box as it appears it is spent. 29. Touch up coat concentrator gate t-handles. 30. Correct bent aluminum grating bearing bars at south end of walkway. 31. Remove wood block from catwalk. 32. Verify pH probe is working and calibrated. 33. Verify thermal control is set per manufacturer’s instructions in main control panel. 34. Verify seal of outer door of main control panel (did not appear lined up with mating surface). 35. Verify concentrator gate t-handles open and close gates freely. 36. Complete and pass process operational period. 37. Check photo cell for catwalk light (light was on at time of inspection). 38. Clean rust from stainless steel at main control panel exterior air conditioners. 39. Add strap to secure grating behind main control panel (grating leaf was loose). 40. Clean and/or touchup coat rust spots on reactor mechanism. Page 4953 of 7162 Original Substantial Completion Date: 6/14/2021 Original Final Completion Date: 7/13/21 Number of Days: 300 Days to Substantial, 330 Days to Final Effective Date Days Added by CO Days between Suspend/Resume Work Revised Substantial Completion Revised Final Completion Total Days Remaining at Suspend Work Letter BCC Agenda Item Procurement Administrative Report Change Order # 1 5/25/2021 66 8/19/2021 9/17/2021 6/22/21 16.E.5 Suspend Work (#1)6/4/2021 105 Resume Work (#1)6/28/2021 24 9/12/2021 10/11/2021 Suspend Work (#2)7/3/2021 100 Change Order #2 7/28/2021 0 Resume Work (#2) 8/17/2021 45 10/27/2021 11/25/2021 Change Order # 3 9/1/2021 0 10/27/2021 11/25/2021 Change Order # 4 10/12/2021 78 1/13/2022 2/11/2022 11/09/21 16.E.8 Suspend Work (#3)12/23/2021 50 Resume Work (#3) 12/28/2021 5 1/18/2022 2/16/2022 Change Order #5 1/12/2022 32 2/19/2022 3/20/2022 2/22/2022 16.E.3 Change Order # 6 3/7/2022 93 5/23/2022 6/21/2022 4/12/2022 16.E.4 Suspend Work (#4)6/20/2022 1 Change Order #7 6/19/2022 108 TBD TBD 7/12/2022 16.E.2 Resume Work (#4)6/28/2022 8 9/16/2022 10/15/2022 Change Order #8 9/9/2022 139 2/2/2023 3/3/2023 9/27/2022 16.E.11 Suspend Work (#5)12/22/2022 71 Resume Work (#5)1/18/2023 27 3/1/2023 3/30/2023 Suspend Work (#6)1/20/2023 69 Resume Work (#6)2/22/2023 33 4/3/2023 5/2/2023 Suspend Work (#7)2/25/2023 66 Resume Work (#7)3/28/2023 31 5/4/2023 6/2/2023 Suspend Work (#8)3/29/2023 65 Resume Work (#8)4/6/2023 8 5/12/2023 6/10/2023 Suspend Work (#9)4/7/2023 64 Resume Work (#9)4/25/2023 18 5/30/2023 6/28/2023 Suspend Work (#10)4/29/2023 60 Resume Work (#10)7/10/2023 72 8/10/2023 9/8/2023 Suspend Work (#11)7/25/2023 45 Resume Work (#11)9/18/2023 55 10/4/2023 11/2/2023 Suspend Work (#12)9/28/2023 35 Resume Work (#12)10/4/2023 35 10/10/2023 11/8/2023 Suspend Work (#13)10/5/2023 34 Change Order # 9 14 Resume Work TBD CHANGE ORDER DAYS TOTAL 530 Page 4954 of 7162 Instructions After the Fact Form As per section 21 of the Procurement Manual, all purchases shall be consistent and in compliance with the Procurement Ordinance (2017-08). Should work be authorized or purchases made that is inconsistent with County policy, procedure, or contract terms, an After-the-Fact Procurement Form is required. This includes purchases made in advance of a Purchase Order, when a Purchase Order is required to authorize such activity, and purchases made under an expired contract, or for goods and services not covered by the current contract or purchase order. All such “After the Fact Procurements” will be reported to the County Manager. Requester Name: Division: Division Director: Vendor Name: Amount: Contract #: Purchase Order: Why is this deemed a non-compliant purchase? Choose one. Contract Ordinance Manual P-Card Other Details of Purchase: Explain the circumstances behind this purchase. Action Required: What are you asking to be done to remedy the situation, include list of invoices if applicable? Corrective/Preventive Action: What action is being taken to prevent this violation from re-occurring? The requestor affirms that to the best of their knowledge the information provided in this document is true. Requested by: Signature: Date: Division Director: Signature: Date: Department Head: Signature: Date: Reviion#1: February 2024 Page 4955 of 7162