Loading...
Agenda 08/22/2023 Item #16L 1 (Six-month extension between the CRA and Southern Region Development, LLC for the property at 2600 Davis Blvd.)08/22/2023 EXECUTIVE SUMMARY Recommendation that the Board of County Commissioners, acting as the Community Redevelopment Agency Board (CRA), approve a six-month extension of the project completion date set forth in the Commercial Building Improvement Grant (CBIG) Agreement between the CRA and Southern Region Development, LLC, for the property located at 2600 Davis Boulevard, Naples, Florida 34112 located within the Bayshore Gateway Triangle Community Redevelopment Area. OBJECTIVE: To approve a six-month extension for the Commercial Building Improvement Grant Agreement between the Community Redevelopment Agency (CRA) and Southern Region Development, LLC, due to the impact of Hurricane Ian, which flooded the existing buildings, incapacitated hundreds of pieces of eq uipment, and redistributed the 3 feet of fill that had just been delivered on site and allow the project to be completed and grant funds to be disbursed. CONSIDERATIONS: On July 1, 2021, Sunbelt executed a Commercial Building Improvement Grant (CBIG) Agreement with the CRA to improve the exterior of the commercial property located at 2600 Davis Boulevard. The Grantee utilized the lowest bid of $82,935.00 for the project, which resulted in a total grant award of $30,000. As set forth in the attached CBIG Agreement, Paragraph 4 required the improvements to be completed by July 13, 2022. However, the CBIG Program provides the CRA with the discretion to approve time extensions for projects provided that the grantees can verify that “applications for permi t were submitted to Collier County within four months after execution of the grant agreement and that construction of improvements commenced within six months after execution of the grant agreement.” On April 12, 2022, the CRA Board granted a time extension of the required project completion date due to material shortages outside of the grantee’s control. As a result, the revised completion date became July 13, 2023. Since the granting of the first extension, the grantee has been diligently carrying out the desired building improvements. Unfortunately, the project and underlying business were severely impacted by Hurricane Ian, which introduced new delays. While the grantee has, for the most part, overcome these delays and is currently awaiting a temporary certificate of occupancy, the project will not be closed out prior to the July 13th deadline, and the grantee has requested a second time extension. The subject request is for six months, which would result in a new completion deadline of January 13, 2024. Based upon the status of the project, remaining items of work, and the grantee’s project schedule, both the grantee and CRA staff believe that the second extension will provide enough time for the project to be completed. The grantee has shown good faith and has turned an uninspiring metal building into something creative and inspiring for a use that is typically found in an industrial park. GROWTH MANAGEMENT IMPACT: None ADVISORY BOARD RECOMMENDATION: On June 29, 2023, the Bayshore Gateway Triangle CRA Local Redevelopment Advisory Board reviewed the request for extension and recommended approval. This recommendation was approved with a vote of 7-0. LEGAL CONSIDERATIONS: This item is approved as to form and legality, and it requires a majority vote for approval. (HFAC) FISCAL IMPACT: No additional fiscal impact. Funding in the amount of $30,000 was budgeted at the time of the grant approval and is available in BGTCRA Capital Fund 1021, Project No. 50198 RECOMMENDATION: The Board of County Commissioners, acting as the Community Redevelopment Agency Board (CRA), approve an Agreement with a six-month extension of the project completion date set forth in the Commercial Building Improvement Grant (CBIG) Agreement between the CRA and Southern Region 16.L.1 Packet Pg. 1059 08/22/2023 Development, LLC, for the property located at 2600 Davis Boulevard, Naples, Florida 34112 located within the Bayshore Gateway Triangle Community Redevelopment Area. Prepared by: Tami Scott, Project Manager, BGTCRA ATTACHMENT(S) 1. 1-Staff Report and photos Advisory Board 6-29-23 (PDF) 2. 2-Request for 2nd time extension (PDF) 3. 3-CRA Grant Extension Recording (Item #16B1 4-12-22 BCC Meeting) (PDF) 4. 4-Original-Commercial Building Improvements Grant (PDF) 5. 5-2023-7-7 CRA CBIG second Amendment (PDF) 16.L.1 Packet Pg. 1060 08/22/2023 COLLIER COUNTY Board of County Commissioners Item Number: 16.L.1 Doc ID: 26075 Item Summary: Recommendation that the Board of County Commissioners, acting as the Community Redevelopment Agency Board (CRA), approve a six-month extension of the project completion date set forth in the Commercial Building Improvement Grant (CBIG) Agreement between the CRA and Southern Region Development, LLC, for the property located at 2600 Davis Boulevard, Naples, Florida 34112 located within the Bayshore Gateway Triangle Community Redevelopment Area. Meeting Date: 08/22/2023 Prepared by: Title: – Bayshore CRA Name: Tami Scott 07/12/2023 10:58 AM Submitted by: Title: – Corporate Business Operations Name: Greg Oravec 07/12/2023 10:58 AM Approved By: Review: Corporate Business Operations Jennifer Reynolds Stage 1 Review Completed 07/12/2023 11:14 AM Corporate Business Operations Charles Kammerer Stage 1 Review Completed 07/12/2023 12:14 PM Corporate Business Operations Greg Oravec Director - CRAs Completed 07/12/2023 2:12 PM County Attorney's Office Heidi Ashton-Cicko Level 2 Attorney of Record Review Completed 07/17/2023 2:03 PM Office of Management and Budget Debra Windsor Level 3 OMB Gatekeeper Review Completed 07/17/2023 2:07 PM County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 07/18/2023 9:48 AM Office of Management and Budget Blanca Aquino Luque Additional Reviewer Completed 08/09/2023 2:32 PM Office of Management and Budget Geoffrey Willig Additional Reviewer Skipped 08/11/2023 11:37 AM County Manager's Office Dan Rodriguez Level 4 County Manager Review Completed 08/16/2023 12:32 PM Board of County Commissioners Geoffrey Willig Meeting Pending 08/22/2023 9:00 AM 16.L.1 Packet Pg. 1061 16.L.1.aPacket Pg. 1062Attachment: 1-Staff Report and photos Advisory Board 6-29-23 (26075 : CBIG grant extension) 16.L.1.aPacket Pg. 1063Attachment: 1-Staff Report and photos Advisory Board 6-29-23 (26075 : CBIG grant extension) 16.L.1.aPacket Pg. 1064Attachment: 1-Staff Report and photos Advisory Board 6-29-23 (26075 : CBIG grant extension) 16.L.1.bPacket Pg. 1065Attachment: 2-Request for 2nd time extension (26075 : CBIG grant extension) ORIGINAL DOCUMENTS CHECKLIST & ROUTING SLIP TO ACCOMPANY ALL ORIGINAL DOCUMENTS SENT TO THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR SIGNATURE Print on pink paper. Attach to original document. The completed routing slip and original documents are to be forwarded to the County Attorney Office at the time the item is placed on the agenda. All completed routing slips and original documents must be received in the County Attorney Office no later than Monday preceding the Board meeting. NEW** ROUTING SLIP Complete routing lines#1 through#2 as appropriate for additional signatures,dates,and/or information needed. If the document is already complete with the exception of the Chairman's signature,draw a line through routing lines#1 through#2,complete the checklist,and forward to the County Attorney Office. Route to Addressee(s) (List in routing order) Office Initials Date 1. 2. County Attorney Office County Attorney Office A(2) 5Ak/nr, 4/12 3. BCC Office Board of County Commissioners 14112'22. 4. Minutes and Records Clerk of Court's Office a't lest44).A ,5. Tami Scott Bayshore CRA TS PRIMARY CONTACT INFORMATION Normally the primary contact is the person who created/prepared the Executive Summary. Primary contact information is needed in the event one of the addressees above,may need to contact staff for additional or missing information. Name of Primary Staff Tami Scott Phone Number 239)252-8845 Contact/ Department Agenda Date Item was April 12,2022 Agenda Item Number 16.B.1 Approved by the BCC Type of Document Extension for Grant Agreement between the Number of Original 1 Attached Community Redevelopment Agency and Documents Attached Grantee PO number or account 187/138325/649030 number if document is to be recorded INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable column,whichever is Yes N/A(Not appropriate. Initial) Applicable) 1. Does the document require the chairman's original signature? Sfuw o% TS 2. Does the document need to be sent to another agency for additional signatures? If yes, N/A provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be signed by the Chairman,with the exception of most letters,must be reviewed and signed by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's TS Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the TS document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's TS signature and initials are required. 7. In most cases(some contracts are an exception),the original document and this routing slip TS should be provided to the County Attorney Office at the time the item is input into SIRE. Some documents are time sensitive and require forwarding to Tallahassee within a certain time frame or the BCC's actions are nullified. Be aware of your deadlines! 8. The document was approved by the BCC on 04/12/2022 and all changes made during TS N/A is not the meeting have been incorporated in the attached document. The County an option for Attorney's Office has reviewed the changes,if applicable. this line. 9. Initials of attorney verifying that the attached document is the version approved by the N/A is not BCC,all changes directed by the BCC have been made,and the document is ready for the 90/V7 an option for Chairman's signature. this line. I:Forms/County Forms/BCC Forms/Original Documents Routing Slip WWS Original 9.03.04,Revised 1.26.05,Revised 2.24.05;Revised 11/30/12 16.L.1.c Packet Pg. 1066 Attachment: 3-CRA Grant Extension Recording (Item #16B1 4-12-22 BCC Meeting) (26075 : CBIG grant extension) Receipt# 008555539 4/21/2022 11:03:13 AM Crystal K. Kinzel Clerk of the Circuit Court and Comptroller ctIkc < s 0 i r,Fgij_ 0 . 000\ Customer Deputy Clerk Clerk Office Location PICK UP BOX Deana Jimenez Collier County Govt. Center CLERK TO THE BOARD/MINS Deana.Jimenez@collierclerk.com Building LA, 2nd Floor REC 239) 252-2646 3315 Tamiami Trl E Ste 102 3299 TAMIAMI TRL E STE 401 Naples, Florida 34112-4901 NAPLES, FL 34112 1 Document Recorded DOC TYPE INSTRUMENT BOOK PAGE AMOUNT Agreement 6238700 6114 3102 18.50 TOTAL AMOUNT DUE 18.50 Clerk Account#: BCC 18.50) BALANCE DUE 0.00 Note: 4/21/2022 11:03:13 AM Deana Jimenez: CHARGE ACCOUNT# 187-138325-649030 DEPARTMENT; CORPORATE BUSINESS OPERATIONS Disclaimer: All transactions are subject to review/verification. The Clerk reserves the right to correct for clerical errors and to assess or refund charges as needed. 1©®11 Il®F Vil® @C fCU Page 1 of 1 16.L.1.c Packet Pg. 1067 Attachment: 3-CRA Grant Extension Recording (Item #16B1 4-12-22 BCC Meeting) (26075 : CBIG grant extension) EXTENSION OF PROJECT COMPLETION DATE FOR GRANT AGREEMENT BETWEEN COLLIER COUNTY COMMUNITY REDEVELOPMENT AGENCY AND GRANTEE FOR COMMERCIAL BUILDING IMPROVEMENTS FOR BAYSHORE GATEWAY TRIANGLE COMMUNITY REDEVELOPMENT AREA THIS AGREEMENT ENTERED this 124 day of /9pr I 2022 by and between the Collier County Community Redevelopment Agency (hereinafter referred to as CRA") and Southern Region Development, LLC (hereinafter referred to as "Grantee"). RECITALS: WHEREAS, On July 13, 2021, the Board of County Commissioners approved a Commercial Building Improvement Grant Agreement ("Agreement"), attached, and incorporated by reference as "Exhibit A" in the amount of 30,000.00 dollars with a project completion date of July 13, 2022; and WHEREAS,Material supply shortage have hindered timely completion of the project; and WHEREAS, the Commercial Building Improvement Grant Program allows time extensions of the project completion date if the applications for permits were submitted to Collier County within four months after execution of the grant agreement and construction of the improvements commenced within eight months after execution of the grant agreement; and WHEREAS, the Board finds that circumstances exist to grant a time extension of the required construction completion date and finds that an extension of the project completion date to July 13, 2023 is appropriate. NOW, THEREFORE, in consideration of the mutual covenants contained herein and other valuable consideration, the parties agree as follows: 1. The foregoing Recitals are true and correct and are incorporated by reference herein. 2. The project completion deadline set forth in Paragraph 4 of the Agreement is extended to July 13, 2023. This is the first extension of the project completion deadline. 3. All other terms and conditions of Agreement remains unchanged and are in full force and effect. This First Amendment merges any prior written and oral understanding and agreements, if any, between the parties with respect to the matters set forth herein. IN WITNESS WHEREOF, the parties have executed this Agreement on the day and year first written above. INSTR 6238700 OR 6114 PG 3102 RECORDED 4/21/2022 11:03 AM PAGES 2 CLERK OF THE CIRCUIT COURT AND COMPTROLLER COLLIER COUNTY FLORIDA REC$18.50 1 16.L.1.c Packet Pg. 1068 Attachment: 3-CRA Grant Extension Recording (Item #16B1 4-12-22 BCC Meeting) (26075 : CBIG grant extension) GRANTEE: Southern Region Development, LLC 1) By: W tnes ,Signature Casf}L, Ow er AVA Printed/Ty ed Name 2) es ( /i gnature IdS Printed/Typed Name ATTEST: COLLIER COUNTY COMMUNITY CRYSTAL.:K. KINZEL, Clerk REDEVELOP , • • NCY y: I) Adil°11° Deputy lerk Will:m L. McDaniel, Jr Chairman gnato °nW. Approved as to form and legality: attorney 3 G2 16.L.1.c Packet Pg. 1069 Attachment: 3-CRA Grant Extension Recording (Item #16B1 4-12-22 BCC Meeting) (26075 : CBIG grant extension) INSTR 6102476 OR 5988 PG 829 RECORDED 7/27/2021 9:53 AM PAGES 24 CLERK OF THE CIRCUIT COURT AND COMPTROLLER COLLIER COUNTY FLORIDA REC$205.50 GRANT AGREEMENT BETWEEN CRA AND GRANTEE FOR COMMERCIAL BUILDING IMPROVEMENTS FOR BAYSHORE GATEWAY TRIANGLE COMMUNITY REDEVELOPMENT AREA THIS AGREEMENT ENTERED this(3 day ofNIAtz,t021 by and between the Collier County Community Redevelopment Agency(hereinafter referred to as"CRA"), Southern Region Development, LLC (hereinafter referred to as"Grantee"). WITNESSETH: WHEREAS, Collier County Ordinance No. 2008-61,as amended, authorizes the CRA to award and administer CRA grants such as the Commercial Building Improvement program; and WHEREAS, Grantee has applied for a Commercial Building Improvement Grant in the amount of$30,000; and WHEREAS,the CRA has determined that Grantee meets the eligibility requirements and was approved for a grant award in the amount of$30,000 on the date first written above(CRA Approval"). NOW, THEREFORE, in consideration of the mutual covenants contained herein and other valuable consideration,the parties agree as follows: 1. Grantee acknowledges to the CRA that Grantee has received a copy of the Collier County Community Redevelopment Agency Commercial Building Improvement Grant Program Information and Application(hereinafter referred to as"Grant Program"),that Grantee has read the Grant Program and that Grantee has had ample opportunity to discuss the Grant Program with Grantee's counsel or advisor. Grantee further acknowledges to the CRA that Grantee understands and agrees to abide by all the terms and conditions of the Grant Program. 2. Southern Region Development,LLC is the record owner of property located at 2600 Davis Blvd,Naples, Florida, 34112. 3. Grantee has agreed to make certain improvements to the property pursuant to the grant application submitted to the CRA on the date first written above attached hereto as Exhibit A and incorporated herein by reference. 4. Grantee agrees to complete the construction of the commercial building improvements by July 13, 2022. Grantee also agrees to fund at least 50% of the costs of the commercial building improvements. Grantee is prohibited from paying contractors and/or vendors with cash. All payments for approved projects must be in the form of a check or credit card drawing on funds from Grantee's accounts. All receipts and invoices must reconcile against payments. 5. The CRA has approved a grant to Grantee in the amount of$30,000 to be administered pursuant to the terms of this Agreement based on an estimated cost of$82,935.00. If the 16.L.1.d Packet Pg. 1070 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) actual costs are less than $60,000 to construct the improvements,the grant amount shall be reduced dollar for dollar in CRA funds as determined by ratio of matching private funds required. 6. Unless prior disclosure is included in the grant application,no Grantee, or any immediate relative of Grantee, shall serve as a contractor or subcontractor for the construction of the improvements and no Grantee, or any immediate relative of Grantee, shall receive compensation for labor for the construction of the improvements. An immediate relative of Grantee shall include mother, father, brother, sister, son, daughter, aunt,uncle and cousin or family member by marriage to include mother-in-law, father-in-law,brother-in-law and sister-in-law. Grantee has verified that all contracts who have provided bids for the approved work are actively licensed by Collier county or the State of Florida. Grantee acknowledges that the total grant award shall not exceed the sum of lowest bids/price quotes for all projects. Grant funds for work performed by contractors shall only be disbursed upon verification that said contractors are actively licensed by Collier County or the State of Florida. 7. Grantee agrees to obtain all necessary permits and submit any required plans to the County's Growth Management Department. Upon completion of the work, Grantee shall submit to the CRA staff a Project Summary Report,two 8 inch by 10 inch photos showing the improvements a list of materials and construction techniques used, a list of architects and/or contractors, and any other information specific to the project or requested by the CRA staff. The CRA,through its staff, shall confirm that the Commercial Building Improvements were constructed pursuant to the terms of the application approved by the CRA. 8. Within forty-five(45)days after confirmation that the improvements were constructed pursuant to the terms of the approved application,the Grantee shall be issued a check in the amount of the grant. However, if the Grantee fails to make the improvements pursuant to the terms of the approved application, or if the improvements are not completed by July 13, 2022,the grant shall be deemed revoked and Grantee shall not be entitled to funding. 9. This Agreement shall be governed and construed pursuant to the laws of the State of Florida. 10. This Agreement contains the entire agreement of the parties and their representatives and agents, and incorporated all prior understandings,whether oral or written.No change, modification or amendment,or any representation, promise or condition,or any waiver,to this Agreement shall be binding unless in writing and signed by a duly authorized officer of the party to be charged. 11. This Agreement is personal to Grantee and may not be assigned or transferred by Grantee or to Grantee's respective heirs, personal representatives, successors or assigns without the prior written consent of the CRA. 16.L.1.d Packet Pg. 1071 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 12. Should the property be transferred, sold, or the Grantee otherwise divested of its interest,or fail to maintain the improvements during the five-year period following receipt of grant funds,the CRA must be reimbursed the grant funds. 13. This Agreement shall be recorded in the Public Records of Collier County,Florida. IN WITNESS WHEREOF,the parties have executed this Agreement on the date and year first written above. GRANIbE(s): Southern Region Development, LLC 1) By: `4.;, 4 '°\ Wit ess S nature Signature) John Caskey,Registered Agent 1' Printed/Typed Name 2) „ti c..W W ' ess Signat re Printed/Typed Nar je ATTEST: COLLIER COUNTY COMMUNITY CRY `AT , "KINZEL, Clerk REDEVEL P T AGENCY By:011A1 Lidt4/t 4 fig°'. ToGyClerk v a lature,ply:,,* Penny Taylor, Chairperson Q. \ CD Apprbved as to form and legality: 52' Jemrife A.Belpedio Assistant County Attorney 2 16.L.1.d Packet Pg. 1072 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) EXHIBIT b N 3299 Tamiami Tr(E Ste 103 C) I Naples Fl 34112 www.bayshorecra.com Bayahore Gateway Triangle CRA i Commercial Building Improvement Grant Application C-BIG Application (Detach and submit to CRA office.) Applicant Information Grantee Name felltz, CL-C-`tps'v)rr \) Grantee Address c ,S,u4 C y „( Site Address Daytime Phone C2.51)3.7 t.3 .3 Alternate Phone E-Mail Address _.V..)At Cr 5, si-; Do you own or lease the property? Occupational License No. if applicable) Project Information Describe the existing conditions of the site(attach additional sheets if necessary}. eks ti<< F z.`,c 1 t,.' )S )-s r L i i i d4N4.3 \ C6:4uI-r) Outline the proposed improvements in detail(attach additional sheets if necessary). aC` c•: c.t j= a1 Cl ti' - ram,: r=.^1k:` CS _) 1 c. p71 ova l l.Q1:tu't;1).'\ I'I \(-'11\II.\"I:S I'It()1l ,\1'1'I.I(•\iN I 11 ()lie r,ti 1i ie cash Iron( 11tO contiactoi lot each projcci. I lir.r muactrr lll',ti F lw;ern>•.rl I 13usiucss Ownct's: cult\ (II nccnpatiuiuil lir(n.c. CRA STAFF Estimated cost of improvements $ . . 1) ',Attach two color photos of each project to be performed. Maximum grant award:: 2) Attach.Property Appraiser ID. Signature:. Date3) Attgehproof of payment of property taxes:' 16.L.1.d Packet Pg. 1073 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 3299 Tamiami Trl E Ste 103 Naples Fl 34112 www.bayshorecra.com Bayehore Gateway Triangle CRA J Commercial Building Improvement Grant Application C-BIG Application (Detach and submit to CRA office.) Applicant Information Grantee Name tz r t zti r'e A S; +=\ ' t-•(.. Grantee Address t :l• G S Site Address 1 1,.ti 21y.91 :.+, tea. i lCY Kj P4 S.) 'L-• c606—v-n- 1 i=-) 4 I I Daytime Phone L-2_..„,:0. 7 t3-i3 Alternate Phone E-Mail Address lA tiCA-s4c Do you own or lease the property? Occupational License No. if applicable) Project Information Describe the existing conditions of the site(attach additional sheets if necessary.S—ctic: € e' C s E- ) 4 Outline the proposed improvements in detail(attach additional sheets if necessary). C:-`- t • Cs'_s a\ "h v ••`jam<, ',=-;"' • i lt'`'C'- cI) n\` 1 3•- '`3) -M 1 0\)M i f ay r C.. t NI'.O('TRH):1"11AC:11\11.'1'.ti l RO l :11'1'1.I( :1iN I; I) Ohtr rtim:rlc each IYunt 'I\1O contractor% hir each project. 1 h;:,; a i1r. iurs\1t 1 I,, hrt n, ti. 21 Bushiest.( n&rti: coi)\ nl uct iipaliunal lie(um). CRA STAIT: Estimated cost of improvements: $ 1) .Attach two color photos of each project to be performed Maximum grant award:.. t) Attach Property;Apprttl'serID Signature. Date:.3). Attach proof of pAymeft of Property tiYtei' 16.L.1.d Packet Pg. 1074 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 3299 Tamiami Trl E Ste 103 Naples Fl 34112 www.bayshorecra.com Bayshore Gateway Triangle CRAJ Commercial Building improvement Grant informal^s Grantee Project Summary & Evaluation (attach additional sheets as necessary) Project Summary Describe the improvements made. I,, td!lc.i: t:xt73- ice G— I L+N+: = ry Cam i C— c 5s 1), . P-V? 4 S. y'gcv--m 'C :i t try.. Atv:LIti &\ FEN( List all vendors/contractors providing materials or services for this project with contact information. Vendor/Service Provider Phone Number or Address or Website a)A7.5 Ct',A' T‘r 3:t 3 71A—X-*3`5_. fA .3k, s? j- i) 5-Fs- Grantee Signature Date Grantee Signature Date CRA Staff:Color photos of completed project from site visit must be attached to this report. 16.L.1.d Packet Pg. 1075 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 46, ira7.ist.74Eoom Bayshore Gateway Triangle CRA Applicant Commitment of Resources I /we, ..\CA\r.) (A,- 5,-'c) MA ;*5 owner(s) /tenant(s) of the commercial property located at 2 7.r . r: FA,ell have the funding and all other capability necessary to begin the site improvements listed above and have the ability to complete all improvements within one year of the approval of the improvement grant by the Collier County Community Redevelopment Agency. I / we further affirm that payment for all work on approved improvements will come from accounts in my/our name(s)or the name(s) of entities registered in the State of Florida which I/we have incorporated or otherwise registered with the state(verification is required). Payment for improvements by from persons or entities not a party to this Grant Application is grounds for disqualification. Signature of Tenant(if leased) Date Signature of Tenant(if leased) Date if jointly leased) f Signature of Owner Date Signature of Owner Date if jointly owned) 3299 Tamiami Trail E Suite 103 Naples Fl 34112 www.bayshorecra.com 16.L.1.d Packet Pg. 1076 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 44 t,„)ihf 4 j,:f of -n A .., '110 j I i 1. 4 f 00 1 1 ( 1 4 ti Jr1I _ t., re6, ,_ 1jon• -- ›-'• ' isir. _.•...,-A 1. i z r ' r-,r i.:, rr—_ :_._•-_. ar c—x GI V Iv C V QJ r• a) e em 2Q co v9 CU o 6. ro O 0 o w Lacoma q C.) 0WQU II II N CI) srA f m m OIno 16.L.1.d Packet Pg. 1077 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 4i,D1 y rs i` y r 4Y J .a;;,M' D: wit• py t,.4,,0_...• wfy, , w a f 41C t' •D v ` +Y a( rt f;;y • t -( •a4 S". r a Y CD tifiYf AA' i#cc, 114, r X". M i 1S > J;_ 16.L.1.d Packet Pg. 1078 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) V2e Bayshore Gateway Triangle CRA•Bayshore Beautification MSTU Haldeman Creek MSTU June 7,2021 Bayshore Gateway Triangle CRA Commercial Building Improvement Grant(CBIG) Applicant: Southern Region Development,LLC CIO John Casey—Property Owner 2447 Breakwater Way Naples Florida, 34112 Project location: Sunbelt Facility 2600 Davis Boulevard Naples Florida 34104 Project Scope: A new rental facility is being built at 2600 Davis Boulevard; the property currently has a chain link fence that is in poor condition. The property owner would like to install a new PermaWall Stone Finish fence to replace the existing chain-link fence. The second quotes are for 7' Series A 3 channel black aluminum municipal grade(3) 5' walk gates, (2) Cantilever gates(24' and 16'). Estimates: 1. Fence 2. Gates lA—Coastal Concrete Products,Port Charlotte Florida$46,200.00 (lowest bidder) 1 B—Permacast,Bradenton, Florida $60,728.00 2A—Arc Tech Construction Svcs,LLC $36,735.00(lowest bidder) 2B—Louis Morrello Construction, Inc.dba RS Construction$38,560.00 Lowest Bid Total $82,935.00 CRA contribution 50%or a Max of$30,000.00 CRA contribution for this application$30,000 Offices: 3299 Tamiami Trail E suite 103Naples,Florida 34112 Phone: 239-252-8844 Online: www.BGTCRA.com 16.L.1.d Packet Pg. 1079 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 1A-CBIG Grant-Southern Region Development,LLC-Property location 2600 Davis BLVD.Naples Florida Lowest Bidder) faasat A) or,cts Proposal fan Coastal Concrete Products, LLC 7742 Allco RD This(239)206.4079 Fort Myers,FL33912 Fax(239)334.1390 CGC41610460 To:RS Construction of SW Florida Phone:941-970-8490 Fax: Address:1225 Tamiami Tr Suite A8 Job Name:Sunbelt Attn: Ray Smith Olty,State,Zip Code:Port Charlotte,FL Job Wootton:Naples 33953 Date of Plans: 5/21/20 Job Phone: Date: 6/8/2021 EMI: Labor and material to Install 800 linear feet of 7'tall pre-cast stackable concrete fence. Color to be standard light brown Permitting by Coastal Concrete Products,LLC Fence to be manufactured and installed as per engineered drawings. Price is based on normal digging conditions o Price Is based on 150 mph wind zone exposure B Not Inoludeu4 Coastal Concrete Products,LLC.assumes no liability for underground utilities. Clearing,grading or fill to proper elevations. f Survey If necessary by others. Rock excavation if necessary. Owner/Builder Is Reso_onsibie for the foilowindl To inspect materials for proper color,shape prior to Installation All underground utilities,sprinkler pipes,electrical eleeving eto. Dumpster provided on site. Staked Location of wall WOOD LOOK $46,000. STONE LOOK$40,200. 26%Deposit required prior to manutaoture of material This Proposal stihJestiosIlfifigp after 30 Days Sales Person: Tim Wlnechel 16.L.1.d Packet Pg. 1080 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) Collier Comity GMD Public PortalFLORIDA License Application Status C36259 In order to view fees or view conditions,you need to he signed in. Note:You can collapse and expand individual sections by clicking the header of the section you wish to collapse/expand. License Application Summary Application Number: C36259 Business Name: COASTAL CONCRETE PRODUCTS,LLC License Type: Contractor Application Status: Active Description of Business: All Certificates from CDPlus:36259 Mailing Address: 7742 ALICO RD FORT MYERS FL 33912 Cwalkup@coastalconcreteproducts.com Portal Licensee Status Details licensee Details: COASTAL CONCRETE PRODUCTS,LLC,Address:7742 ALICO RD,Phone: 239)263-9700,State Reg#'s CGC1519460,Licensee#C36259 Issuances Type iiii, Date Issued Date Expires Status Number GENERAL CONTR.-CERTIFIED 09/10/2020 08/31/2022 Active 36259 GENERAL CONTR.-CERTIFIED 09/18/2018 08/31/2020 Expired 36259 Insurance Producer iiit Type Policy Effective Date Expiry Date Limit, GULFSHORE Worker's WC675866500 11/17/2014 11/17/2021 INSURANCE,INSURANCE,INC Compensation GULFSHORE General Liability GL00743477702 11/17/2014 11/17/2021 $2,000,000.00 INSURANCE,INC J DAVID E TORRES ,Worker's Comp QUALIFIER) 12/16/2014 , 12/16/2020 j Exemption 16.L.1.d Packet Pg. 1081 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 1B- CBIG Grant -Southern Region Development,LLC-Property location 2600 Davis BLVD.Naples Florida ' Not Used) 4, ..;;. is i The t0stt:5r clahvory or,b7u,ire,':: vo,t 14' !h;. State License#:CBC 1268823 Project Name: Sunbelt Quotes Number:00000850 Project#: 2782 Expiration Date: May 10,2021 Permacast Wails Contact Information • Sales/PM: Nick Solomon Sales Manager: Steven Hatcher Email: nick@permacastwalls.com Email: steven@permacastwalls.com Phone: 888)977-9255 Phone: 888)977-9255 Mobile: 17274580018 Mobile: 18137204720 Job Site Address&Main Contact Job Site Street: 2600 Davis Blvd Contact Name: Ray Smith Job Site City: Naples Phone: 941)628-8407 Job Site State: FL Email: mbrsconstcgmaii.com Job Site Zip Code:34104 Billing Information Bill To Name: RS Developement Bill To Address: 1225 Tamiaml Trail,Port Charlotte, FL 33953 Description:Furnish and Install 6041f of up to 8'2.0 PermaWall Sand Quote Line Items Product Name Line Item Description Quantity Sales Total Price Price PermaWall 2.0-8ft Furnish&Install 8'H PermaWall 2.0(20'O.C.)Stone Finish 604LF $88.00 $53,152.00 Sand Initial Permit Processing fee and actual permit fees up to$1000 any 1 $1,500.00 $1,500.00 Running Fee additional fees paid by owner at cost via CO. Standard Paint- Permacast Specified Sherwin Williams Flex Lox Paint 604LF $9.00 5,436.00 One Color Cap-8.5x14-Decorative Column Cap 32 $20.00 $840.00 Deco Totals Grand Total: $60,728.00 Wind Load Exposure Per LF Ease Price Is based on*: 160 e 0 Should actual rating be determined higher than estimated,buyer Is responsible for associated cost difference. www.cermacastwalls.com 1 6015 21st St. E, Bradenton,Florida 34203 • (941)234-8879 Phone Initial. 16.L.1.d Packet Pg. 1082 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) GM!) Public: Portal License Application Status C33260 In order to view fees or view conditions,you need to be signed in. Note:You can collapse and expand Individual sections by clicking the header of the section you wish to collapse/expand. License Application Summary Application Number: C33260 Business Name: PERMACAST LLC License Type: Contractor Application Status: Active Description of Business: All Certificates from CDPlus: 33260 - 4/15/2020:See Comments Mailing Address: 6015 21ST STREET E BRADENTON FL 34203 Carlos@permacastwalls.com Portal Licensee Status Details Licensee Details: PERMACAST LI.C,Address:6015 21ST STREET E,Phone:(941)234-8879, State Reg#'s CBC1256823,Licensee#C33260 Issuances Type Date Issued Date Expires Status Number BUILDING CONTR.-CERTIFIED 01/29/2021 08/31/2022 Active 33260 BUILDING CONTR.-CERTIFIED 04/15/2020 08/31/2020 Expired 33260 Insurance Producer__.._._.._.,._.....__...,._._..._......._.....__.........__.-.......____...------.._.._._._._..._.._._.__.._.................._.._-----------------------....—•----___-.—..___,Type Policy Effective Date Expiry Date Limit GIFFORD-HEIDEN INS Worker's 196-49962 01/08/2020 01/08/2022 NG/VG Compensation GIFFORD-HEIDEN INS General Liability 20681471 03/28/2020 03/28/2021 $3,000,000.00 NG/VG 16.L.1.d Packet Pg. 1083 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) O O O FENCE DESIGNS BY ARCTECH PROPOSAL FROM ARC TECH CONSTRUCTION SERVICES, LLC CGC1516497 7742 Alico RD Tel: (239)263-1188 Fort Myers,FL 33912 Fax:(239)263-1058 To: RS Construction of SW Florida Phone: 941-979-8490 Fax: Address: 1225 Tamiami Tr Suite 8A Job Name: Sunbelt Attn: Ray Smith City,State,Zip Code: Port Charlotte,FL Job Location: Naples 33953 Date of Plans: Job Phone: Date: 5/24/2021 Labor and material to install 7'Series A 3 channel aluminum black Municipal grade fence to include r 24'and 16'cantilever gates and three(3)5'walk gates with lock boxes (locks by others) Permit by Arc Tech Construction Services, LLC Price is based on normal digging conditions Not Included Arc Tech Construction Services, LLC.assumes no liability for underground utilities. Clearing,grading or fill to proper elevations. Survey and location markings by others. Owner/Builder is Responsible for the following: To inspect materials for proper color,shape prior to installation All underground utilities, sprinkler pipes, electrical sleeving etc. Staked Location of fence- BID TOTAL This Proposal subiect to change after 30 Days 36,735.00 Sales Person: Tim Winschel Acceptance of Proposal I agree to the above prices,specifications and conditions. I authorize you to begin work as scheduled. I agree to full payment on completion of the work. Signature Officer Signature/Title Print Name: Date: 16.L.1.d Packet Pg. 1084 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) Collier Comity GMD Public PortalfLOHM License Application Status LCC20110003177 In order to view fees or view conditions,you need to be signed in. Note:You can collapse and expand individual sections by clicking the header of the section you wish to collapse/expand. License Application Summary Application Number: LCC20110003177 Business Name: ARC TECH CONSTRUCTION SERVICES,LLC License Type: Contractor Application Status: Active Description of Business: Mailing Address: 7742 ALICO ROAD FORT MYERS FL 33912 Cwa Ikup@coa stalconcreteprod ucts.com Portal Licensee Status Details Licensee Details: ARC TECH CONSTRUCTION SERVICES,LLC,Address:7742 ALICO ROAD, Phone:(239)263-1188,State Reg#'s CGC1516497,Licensee# LCC20110003177 Issuances Type Date Issued Date Expires Status Number GENERAL CONTR.-CERTIFIED 12/01/2020 108/31/2022 Active 201100001550 GENERAL CONTR.-CERTIFIED 11/30/2018 108/31/2020 Expired 201100001550 Insurance Producer Type Policy Effective Date Expiry Date Limit GULFSHORE General Liability ENP0544908 07/15/2020 07/15/2021 $2,000,000.00 INSURANCE-SWFL GULFSHORE Worker's TWC3895852 07/15/2020 07/15/2021 INSURANCE-SWFL Compensation Street Address: Exclusions DAVID E TORRES Worker's Comp QUALIFIER 12/15/2016 01/24/2021 Exemption 16.L.1.d Packet Pg. 1085 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 206 Fletcher St. Mort Charlotte.Fl 33952 one#;(941)276-9750 3C1256593 loiw Norreio toiislricl/oi,, ija. S Construction of SW Florida Famiami Trail A-8 r t..narlotte.FL 33952 nE: Sunbelt Rental Naples Fencing Quote osae of work: Installation of a 7'Series A 3 channel black aluminum Municipal grade fencing to include(21 cantilever gates(24'and 16')and(3)5'walk gates. Permit to be provided by contractor. Please note: alterations or deviations from the above specifications involving extra costs will be executed only upon written orders and will become an extra charge,over and above the estimate/ proposal. This estimate/proposal may be withdrawn by us if not accepted within 30 days. Please Initial Acceptance of Proposal/Estimate: The above prices.specifications and conditions are aciorv.ana the aeoosit is paid,this is hereby accepted as a legal and binding contract. You I nuis Morrello Construction.lnc.1 are authorized to do the work specified. Payment will be made as outlined below. NO WORK WILL BE PERFORMED WITHOUT AN AUTHORIZED SIGNATURE** TOTAL JOB COST: S38.560.00 20%DEPOSIT: S7.712.00 I I IE 1JPON COMPLETION: S30,848.00 cceoted By: 7n'eture of Acceptance Date Louis Morrello.Manager Date 16.L.1.d Packet Pg. 1086 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) r1s Ron DeSantis,Governor Halsey Beshears,Secretary 1;4 db . r STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD THE BUILDING CONTRACTOR HEREIN IS CERTIFIED UNDER THE PROVISIONS OF CHAPTER 489, FLORIDA STATUTES 44,;---_--ZILit;1:::::: :-. ::-..:: i:j...-:1:----:2 "A"re%' MORRELLO, LOUIS ANTHONY R.S. DEVELOPMENT OF SOUTH WEST FLORIDA L.L.C. 1225 TAMIAMI TRAIL UNIT A 8 PORT CHARLOTTE FL 33953 LICENSE NUMBER:CBC1256593 EXPIRATION DATE: AUGUST 31,2022 Always verify licenses online at MyFloridaLicense.com 1#.,f• Do not alter this document in any form. o' This is your license. It is unlawful for anyone other than the licensee to use this document. 16.L.1.d Packet Pg. 1087 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) Collier County Property Appraiser Property Summary Site 2600 Site Zone Parcel No 70820320000 Address DAVIS Site City NAPLES Note 1 34112 Disclaimer BLVD 1 Name/Address 'SOUTHERN REGION DEV LLC 2447 BREAKWATER WAY#8-201 City NAPLES State FL Zip 34112 Map No. Strap No. Section Township Range Acres *Estimated 5A11 601900 255A11 11 50 25 0.81 Legal 'LOT CREEK PINES UNIT 2 LOTS 25 + 26 + FOLL DESC, E 85FT OF W 339.4FT OF g LOT 29, NGTCLF 2 Millage Area 0 112 Millage Rates 0 *Calculations Sub./Condo 601900 - ROCK CREEK PINES UNIT 2 School Other Total Use Code 0 11 - STORES, ONE STORY 5.016 6.2924 11.3084 Latest Sales History 2020 Certified Tax Roll Not all Sales are listed due to Confidentiality) Subject to Change) Date j Book-Page Amount Land Value 638,1511 05/11/17 p393-1344 0 (+) Improved Value 271,2561 05/11/17 5393-1342 0 (_) Market Value 909,407 04/23/03 3272-2731 0 (-) 10% Cap 28,097 04/23/03 3272-2729 0 04/23/03 3272-2727 0 0) Assessed Value 881,310 04/23/03 3272-2725 0 0) School Taxable Value 909,407 04/23/03 3272-2723 0 j (_) Taxable Value 881,3101 04/23/74 586-1425 0 IFinf aalll ValuTax Rolles shown above equal 0 this parcel was created after the 16.L.1.d Packet Pg. 1088 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 1 2020 Paid Collier County Notice of Ad Valorem Taxes and Non-Ad Valorem Assessments if Paid By j Nov 30,2020 Please Pay I $0.00 i Parcel Number ___Legal Description Mill Code Escrow Code 70820320000 ROCK CREEK PINES UNIT 2 LOTS 25+26+FOLL DESC,E 85FT 112 OF W 339.4FT OF LOT 29, 1.NGTCLF 2 I SOUTHERN REGION DEV LLC 2447 BREAKWATER WAY#8-201 Pay In U.S,Funds Drawn ona U.S.Bank To: NAPLES,FL 34112 Collier County Tax Collector 3291 E.Tamiami Trail Naples, FL 34112-5758 POST DATED CHECKS ARE NOT ACCEPTED AND WILL BE RETURNED Walt our websits:www.colliertaxcollector.com Assessed Value District Mill Rate Assessed Value Exempt Amt Taxable Value Tax Amount 881,310 GENERAL FUND 3.5645 881,310 0 881,310 3,141.43 plea,WATER MANAGEMENT FUND-SOUTF 0.1103 881,310 0 881,310 97.21 RetalrBIGCYPRESSBASIN0.1152 881,310 0 881,310 101.53 thisExemptionsSCHOOLBOARD-STATE LAW 2.7680 909,407 0 909,407 2,517.24 portlolSCHOOLBOARD-LOCAL BOARD 2.2480 909,407 0 909,407 2,044.35 forgotCOLLIERMOSQUITOCONTROL0.1662 881,310 0 881,310 148.47 recordGREATERNAPLESFIRERESCUEDIE1.5000 881,310 0 881,310 1,321.97UNINCORPGEN-MSTD 0.8069 881,310 0 881,310 711.13C.C.WATER POLLUTION CTRL PGM 0.0293 881,310 0 881,310 25.82 Miliage Total 11.3084 Total Ad Valorem 10,107.15 Pay your current taxes online at: Non-Ad Valorem District Type of Assessment Amounthttp://www.colllertaxcoliector.coml Non-Ad Valorem Total 0.00 See reverse side for important information Combined Ad Valorem and Non-Ad Valorem Total 10,107.15 Detach and Return with your Payment) 2020 Paid Collier County Notice of Ad Valorem Taxes and Non-Ad Valorem Assessments If Paid By Nov 30,2020 Please Pay 0.00 Parcel Number Mill Code Escrow Code 70820320000 112 SOUTHERN REGION DEV LLC Legal Description 2447 BREAKWATER WAY#8-201 ROCK CREEK PINES UNIT 2 LOTS NAPLES,FL 34'I 12 25+26+FOLL DESC,E 85FT OF W 339.4FT OF LOT 29, NGTCLF 2 11/18/2020 Amount Pald to Date: 9702,86 Receipt 9 130-21-00281297 Paid By SOUTHERN REGION DEV LLC 16.L.1.d Packet Pg. 1089 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) gRCp\ COLLIER COUNTY 3 . TAX COLLECTOR L14LEG' urh > iu r nti_i!.StiIIfl:InFV > Bill Details Business Tax Account#743447 0 SUNBELT RENTALS,INC. Current owner: SUNBELT RENTALS,INC. Current business address: 2600 DAVIS BLVD O More Details Current business phone: 774-7117 uGet bills by email 2021 Details Account number: 743447 Business start date: 07/01/1974 Physical business location: Collier County Business address: SUNBELT RENTALS,INC. 2600 DAVIS BLVD Business phone: 774-7117 Mailing address: SUNBELT RENTALS,INC. ATTN:LICENSING 2341 DEERFIELD DR FORT MILL,SC 29715 Owners(s): SUNBELT RENTALS,INC. 2341 DEERFIELD DR FORT MILL,SC 29 715 RECEIPTS AND OCCUPATIONS RECEIPT 743447 PUBLIC SERVICES 0.00 EQUIPMENT RENTAL SERVICE RECEIPT 780564 RETAIL SALES 0.00 RETAIL SALES 16.L.1.d Packet Pg. 1090 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) PLORIDA DEPARTMENT 0f SFAIL DIVISION OF CORPORATIONS DIVisIoN of 511440. CORPORATIONS an official Slate of Mtn Ida trrl,cite Department of State / Division of Cotporation5 / Search Records / Search by n ity Name / Detail by Entity Name Florida Limited Liability Company SOUTHERN REGION DEVELOPMENT, LLC Filing Information Document Number L17000068329 FEI/EIN Number 82-0985957 Date Filed 03/27/2017 State FL Status ACTIVE Principal Address 2447 Breakwater Way 8-201 NAPLES, FL 34112 Changed:03/28/2019 Mailing Address 2447 Breakwater Way 8-201 Naples,FL 34112 Changed:03/28/2019 gegistered Agent Name&Address CASKEY,JOHN W,JR. 2447 Breakwater Way 8-201 Naples, FL 34112 Address Changed:03/28/2019 Authorized Person(s)Detail Name&Address Title AMBR Caskey,John W,JR. 2447 Breakwater Way 8-201 Naples, FL 34112 Ann,,.I Dnnnr+c 16.L.1.d Packet Pg. 1091 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) Mnnuat tsaNvr La Report Year Filed Date 2019 03/28/2019 2020 01/13/2020 2021 01/12/2021 Document Imagga 01/12/2021—ANNUAL REPORT Yew image in PDF format J 01/1 3/2020-ANNUAL REPORT View image in PDF format 03/28/2019—ANNUAL REPORT Yew image in PDF format I 01/18/2018—ANNUAL REPORT View image in PDF format I 03/27/2017--Florida Limited Liability View image In PDF format Honda Department of State,Division of Corporations 16.L.1.d Packet Pg. 1092 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) a t' ,\ • Y.., !///' l . Y IA_h•' . f. `, Y L,' '''' r , J'' i 4 f tw r•1 o® Boa o 1 4 4iT i' L) t r I Xird I ® y y J i yi A I r t f+ ' j. l , ti l t i 1 f) fit:. f L i..ql.l li . 1 j 16.L.1.d Packet Pg. 1093 Attachment: 4-Original-Commercial Building Improvements Grant (26075 : CBIG grant extension) 16.L.1.ePacket Pg. 1094Attachment: 5-2023-7-7 CRA CBIG second Amendment (26075 : CBIG grant extension) 16.L.1.ePacket Pg. 1095Attachment: 5-2023-7-7 CRA CBIG second Amendment (26075 : CBIG grant extension)