Bayshore Gateway CRA Agenda 06/29/2023/JJ 5.A.2
L
Bayshore Gateway Triangle CRA .Bayshore Beautification MSTU p
Haldeman Creek MSTU m
Bayshore Gateway Triangle Community Redevelopment Local Advisory Board
Collier County Community Redevelopment Agency (CRA)
AGENDA
Hybrid Virtual Zoom Special Meeting
3299 Tamiami Trail E, BCC Chambers 3ra Floor, Naples, FL 34112
June 29, 2023
6:00 PM
Chairwoman Karen Beatty
Maurice Gutierrez, Michael Sherman, Al Schantzen,
Steve Rigsbee, Kathi Kilburn, Sam Saad, Jr, Kristin Hood, and Jim Talano
1. Call to order and Roll Call
2. Pledge of Allegiance
3. Voting Privileges for Board Members via Zoom
4. Approval of Agenda (Action Item)
5. Adoption of Meeting Minutes
a. June 6, 2023, minutes will be presented next regular meeting
6. Communications
7. Old Business
a. Southern Region Development, LLC, (aka Sunbelt) CBIG Extension Request
(Action Item)
b. Expending Money Outside of CRA Boundary for Sugden Park Pathway (Action Item)
c. Florida Redevelopment Conference October 24-27, Board Member Attendance
8. New Business
9. Public Comments
10. Advisory Board General Communications
11. Next Meeting
a. September 12, 2023, NBG Buehler Auditorium
12. Adjournment
3299 Tamiami Trail E, Unit 103, Naples, Florida 34112
Phone: 239-252-8844
www.bayshorecra.com
Packet Pg. 59
fl, > c2�- �7 mot, '5410rkv
Bayshore Gateway Triangle CRA • Bayshore Beautification MSTU
Haldeman Creek MSTU
STAFF REPORT
Item Sa
TO: Gregory J. Oravec, CRA Director
FROM: Tami Scott, CRA Project Manager
DATE: June 22, 2023
SUBJECT: Commercial Improvement Grant- Southern Region Development, LLC
Request:
Southern Region Development, LLC, (a/k/a Sunbelt) is requesting an additional six-month extension of its
Commercial Building Improvement Grant (CBIG) due to development and construction delays stemmng from
Hurricane Ian.
Background and Analysis:
On July 1, 2021, Sunbelt executed a Commercial Building Improvement Grant (CBIG) Agreement with the CRA to
improve the exterior of the commercial property located at 2600 Davis Boulevard. The grantee utilized the lowest
bid of $82,935.00 for the project, which resulted in a total grant award of $30,000.
As set forth in the attached CBIG Agreement, Paragraph 4 required the improvements to be completed by July 13,
2022. However, the CBIG Program provides the CRA with the discretion to approve time extensions for projects
provided that the grantees can verify that "applications for permit were submitted to Collier County within four
months after execution of the grant agreement and that construction of improvements commenced within six months
after execution of the grant agreement."
On April 12, 2022, the CRA Board granted a time extension of the required project completion date due to material
shortages outside of the grantee's control. As a result, the revised completion date became July 13, 2023.
Since the granting of the first extension, the grantee has been diligently carrying out the desired building
improvements. Unfortunately, the project and underlying business were severely impacted by Hurricane Ian, which
introduced new delays. While the grantee has, for the most part, overcome these delays and is currently awaiting a
temporary certificate of occupancy, the project will not be closed out prior to the July 13t' deadline, and the grantee
has requested a second time extension. The subject request is for six months, which would result in anew completion
deadline of January 13, 2024.
Based upon the current status of the project, remaining items of work, and the grantee's project schedule, both the
grantee and CRA staff believe that the second extension will provide enough time for the project to be completed.
The grantee has shown good faith and has turned an uninspiring metal building into something creative and inspiring
for a use that is typically found in an industrial park.
Recommendation:
Staff recommends approval of a six-month extension of the project completion date set forth in the Commercial
Improvement Grant (CBIG) Agreement between the CRA and Southern Region Development, LLC, (aka Sunbelt)
for the property located at 2600 Davis Boulevard, Naples, Florida 34112 located within the Bayshore Gateway
Triangle Community Redevelopment Area.
Attachment:
1. Email Requesting 2nd Extension
2. Approved Grant Extension
3. CBIG Application
5.A.2
Packet Pg. 60
5.A.2
ScottTami
Subject:
FW: Sunbelt Facility, Davis Blvd, Naples
From: JOHN CASKEY <johncaskey@aol.com>
Sent: Tuesday, May 9, 2023 1:44 PM
To: ScottTami<Tami.Scott@colliercountyfl.gov>
Subject: Sunbelt Facility, Davis Blvd, Naples
Hi Tami.....
L
0
m
0
Q
c
as
a
0
m
as
m
U
0
J
Please accept this email as a request for an extension of the grant for the new Sunbelt facility located at 2600 Davis Blvd,
Naples, FL., which is being developed by Southern Region Development, LLC, the property owner.
The delay is a result of the impact of hurricane Ian, which flooded the existing buildings, incapacitated hundreds of
pieces of equipment, and redistributed the 3 feet of fill that had just been delivered on site.
The construction of the new building is complete and awaiting final inspections required for a temporary Certificate of
Occupancy which will allow Sunbelt to move operations to the new building, as well as the demolition of the remaining
existing buildings, and the completion of landscaping, paving and fencing.
To insure adequate time for completion, we would like to request a six month extension, although we expect to be
finished before then.
Thank you for your consideration and cooperation and please advise if you need anything additional from me
Regards,
John Caskey Jr
Owner
Southern Region Development, LLC
Time Extensions
The CRA understands that redevelopment projects can take more time to complete than is originally anticipated. For
grantees who cannot complete their projects within one year, time extensions may be granted. Grantees needing
extensions must request the extension within two months of the grant's expiration. Note: no extensions can be granted
within the last two weeks of the grant period. 1IMPORTANT.• Grantees must verify that applications for permits were
submitted to Collier County within four months after execution of the grant agreement and that construction of
improvements commenced within six months after execution of the grant agreement.
Packet Pg. 61
5.A.2
EXTENSION OF PROJECT COMPLETION DATE FOR GRANT AGREEMENT
BETWEEN COLLIER COUNTY COMMUNITY REDEVELOPMENT AGENCY AND
GRANTEE FOR COMMERCIAL BUILDING IMPROVEMENTS FOR BAYSHORE
GATEWAY TRIANGLE COMMUNITY REDEVELOPMENT AREA
THIS AGREEMENT ENTERED this _ day of llOri 2022 by and
between the Collier County Community Redevelopment Agency (hereinafter referred to as
"CRA") and Southern Region Development, LLC (hereinafter referred to as "Grantee").
RECITALS:
WHEREAS, On July 13, 2021, the Board of County Commissioners approved a
Commercial Building Improvement Grant Agreement ("Agreement"), attached, and incorporated
by reference as "Exhibit A" in the amount of 30,000.00 dollars with a project completion date of
July 13, 2022; and
WHEREAS, Material supply shortage have hindered timely completion of the project; and
WHEREAS, the Commercial Building Improvement Grant Program allows time
extensions of the project completion date if the applications for permits were submitted to Collier
County within four months after execution of the grant agreement and construction of the
improvements commenced within eight months after execution of the grant agreement; and
WHEREAS, the Board finds that circumstances exist to grant a time extension of the
required construction completion date and finds that an extension of the project completion date
to July 13, 2023 is appropriate.
NOW, THEREFORE, in consideration of the mutual covenants contained herein and
other valuable consideration, the parties agree as follows:
1. The foregoing Recitals are true and correct and are incorporated by reference herein
2. The project completion deadline set forth in Paragraph 4 of the Agreement is extended
to July 13, 2023. This is the first extension of the project completion deadline.
All other terms and conditions of Agreement remains unchanged and are in full force
and effect. This First Amendment merges any prior written and oral understanding and
agreements, if any, between the parties with respect to the matters set forth herein.
IN WITNESS WHEREOF, the parties have executed this Agreement on the day and year
first written above.
INSTR 6238700 OR 6114 PG 3102
RECORDED 4/21/2022 11:03AM PAGES 2
CLERK OF THE CIRCUIT COURT AND COMPTROLLER
COLLIER COUNTY FLORIDA C�(
REC $18.50
Packet Pg. 62
5.A.2
Atnesnature
T
��!'n'�
Printed/TvDed Name
(2)
/Witness Nignature
v n
Printed/Typed Name
Ys-i`.�''�C. KINZEL, Clerk
n°
�rDeputy Jerk
� to Chaimnany
gnatu� ot�W.
Approved as to orm and
legality: 11A
c � \aa-
C my Attorney
3
GRANTEE: Southern Region Development, LLC
By:
fin Caf y Ow er
COLLIER COUNTY COMMUNITY
REDEVELOP NCY
C� C '
By:
Will' m L. McDaniel, Jr Chairman
2
Packet Pg. 63
0
INSTR 6102476 OR 5988 PG 829
RECORDED 7/27/2021 9:53 AM PAGES 24
CLERK OF THE CIRCUIT COURT AND COMPTROLLER
COLLIER COUNTY FLORIDA
REC $205.50
GRANT AGREEMENT BETWEEN CRA AND GRANTEE FOR COMMERCIAL BUILDING
IMPROVEMENTS FOR BAYSHORE GATEWAY TRIANGLE COMMUNITY
REDEVELOPMENT AREA
ON
THIS AGREEMENT ENTERED thisffday of , 021 by and between the Collier
County Community Redevelopment Agency (hereinafter referred to as "CRA"), Southern Region
Development, LLC (hereinafter referred to as "Grantee").
WITNESSETH:
WHEREAS, Collier County Ordinance No. 2008-61, as amended, authorizes the CRA to award
and administer CRA grants such as the Commercial Building Improvement program; and
WHEREAS, Grantee has applied for a Commercial Building Improvement Grant in the amount
of $30,000; and
WHEREAS, the CRA has determined that Grantee meets the eligibility requirements and was
approved for a grant award in the amount of $30,000 on the date first written above (CRA Approval").
NOW, THEREFORE, in consideration of the mutual covenants contained herein and other
valuable consideration, the parties agree as follows:
Grantee acknowledges to the CRA that Grantee has received a copy of the Collier County
Community Redevelopment Agency Commercial Building Improvement Grant Program
Information and Application (hereinafter referred to as "Grant Program"), that Grantee has
read the Grant Program and that Grantee has had ample opportunity to discuss the Grant
Program with Grantee's counsel or advisor. Grantee further acknowledges to the CRA that
Grantee understands and agrees to abide by all the terms and conditions of the Grant
Program.
2. Southern Region Development, LLC is the record owner of property located at 2600 Davis
Blvd, Naples, Florida, 34112.
3. Grantee has agreed to make certain improvements to the property pursuant to the grant
application submitted to the CRA on the date first written above attached hereto as Exhibit A
and incorporated herein by reference.
4. Grantee agrees to complete the construction of the commercial building improvements by
July 13, 2022. Grantee also agrees to fund at least 50% of the costs of the commercial
building improvements. Grantee is prohibited from paying contractors and/or vendors with
cash. All payments for approved projects must be in the form of a check or credit card
drawing on funds from Grantee's accounts. All receipts and invoices must reconcile against
payments.
The CRA has approved a grant to Grantee in the amount of $30,000 to be administered
pursuant to the terms of this Agreement based on an estimated cost of $82,935.00. If the
Packet Pg. 64
5.A.2
actual costs are less than $60,000 to construct the improvements, the grant amount shall be
reduced dollar for dollar in CRA funds as determined by ratio of matching private funds
required.
6. Unless prior disclosure is included in the grant application, no Grantee, or any immediate
relative of Grantee, shall serve as a contractor or subcontractor for the construction of the
improvements and no Grantee, or any immediate relative of Grantee, shall receive
compensation for labor for the construction of the improvements. An immediate relative of
Grantee shall include mother, father, brother, sister, son, daughter, aunt, uncle and cousin or
family member by marriage to include mother-in-law, father-in-law, brother-in-law and
sister-in-law. Grantee has verified that all contracts who have provided bids for the approved
work are actively licensed by Collier county or the State of Florida. Grantee acknowledges
that the total grant award shall not exceed the sum of lowest bids/price quotes for all projects.
Grant funds for work performed by contractors shall only be disbursed upon verification that
said contractors are actively licensed by Collier County or the State of Florida.
Grantee agrees to obtain all necessary permits and submit any required plans to the County's
Growth Management Department. Upon completion of the work, Grantee shall submit to the
CRA staff a Project Summary Report, two 8 inch by 10 inch photos showing the
improvements a list of materials and construction techniques used, a list of architects and/or
contractors, and any other information specific to the project or requested by the CRA staff.
The CRA, through its staff, shall confirm that the Commercial Building Improvements were
constructed pursuant to the terms of the application approved by the CRA.
Within forty-five (45) days after confirmation that the improvements were constructed
pursuant to the terms of the approved application, the Grantee shall be issued a check in the
amount of the grant. However, if the Grantee fails to make the improvements pursuant to the
terms of the approved application, or if the improvements are not completed by July 13,
2022, the grant shall be deemed revoked and Grantee shall not be entitled to funding.
9. This Agreement shall be governed and construed pursuant to the laws of the State of Florida.
10. This Agreement contains the entire agreement of the parties and their representatives and
agents, and incorporated all prior understandings, whether oral or written. No change,
modification or amendment, or any representation, promise or condition, or any waiver, to
this Agreement shall be binding unless in writing and signed by a duly authorized officer of
the party to be charged.
11. This Agreement is personal to Grantee and may not be assigned or transferred by Grantee or
to Grantee's respective heirs, personal representatives, successors or assigns without the prior
written consent of the CRA.
Packet Pg. 65
5.A.2
(2)
12. Should the property be transferred, sold, or the Grantee otherwise divested of its interest, or
fail to maintain the improvements during the five-year period following receipt of grant
funds, the CRA must be reimbursed the grant funds.
13. This Agreement shall be recorded in the Public Records of Collier County, Florida.
IN WITNESS WHEREOF, the parties have executed this Agreement on the date and year first
written above.
Printed/Typed Name
t-1
ATTEST:
CRYS,5"AL .jr10NZEL, Clerk
eS fo r'Y Clerk
9 �1ature
Approved as to form and legality:
GRANTEE(s): Southern Region Development, LLC
By:
cV^
{S'igrrature) t�}}
._.Jolrn Caskey, Registiered Ag7't
COLLIER COUNTY COMMUNITY
REDEVEL P T AGENCY
By:
Jetmife A. Belpedio
Assistant County Attorney �2
Penny Taylor, Chairperson
CDC
Packet Pg. 66
5.A.2
EXHIBIT
3299 Tamiami Trl E Ste 103 E
G
Naples F134112
www.baynshorecra.com
•t%fa�iv'f�aJ•,s.r Beoon�
MEL
Bayshore Gateway Triangle CRA j Commercial Building Improvement t3rant application
GBIG Atilnliratinn in-.e w a ..L--
--- - -- -- -- �•.�••••,.•.. W. - auuwn to URA (i ce.)
Applicant Information
Grantee Name
Grantee Address Address
G�� ;3 z �� G y „(
� A��z
Site Address
z�... r� _�v tS �.��
•�Li•y'-r try
Daytime Phone
LLB'\ -:7 �,�3
J
Alternate
Phone
E-Mail Address
Do you own or lease the property?
Occupational License No.
if applicable)
Project Information
Describe the existing conditions of the site attach additional sheets if necess
�...�C�S � , ti: C� F�C.�[_ � r.' �; ). S Cl-srZ'v�t L i ►�� � c
Outline the proposed improvements in detail attach additional sheets if necessary).
Moi
c>aA STAM:
)Estimated coat of improvements:: �..:.
1) ,Attach two color photos of each project to be
'performed.
Mathnunrgrant award:. $
2) 'Attach.PropertyApproleerID.
3) Attach proof of pa�+mti- of property takes:
' -
Slgpature iD
r
Packet Pg. 67
5.A.2
3299 Tatniami Trl E Ste 103
Naples F134112
www.bayshorecra.com
%tosG�wv%iw �%om
Bays ore Gateway Triangle CRA I Commercial Building improvement Grant Application
C-BIG Application (Detach and b t t c fi
— mt o BA o tce.)
-Name Applicant Information
Grantee
-
�r�Z•t `
'� �zw �. Cam_ fee ,,:..�zi �'���7y�►{��= \ �-�-•�....
1
Grantee Address
j �1,�
Site Address
Daytime Phone
S •:7 t, 33
Alternate
Phone
E-Mail Address.-1
Do you own or lease the property?
Occupational License No.
01
if a'lieable
Project Information
Describe the existing conditions of the site attach additional sheets if necessary).
Outline the proposed improvements in detail attach additional sheets if necessary).
„.� ��._ �_i + L: � � �s_l��'`• 11 �i � �l F-�1%� \^ •�i .}�-� as
1 l�i.�'��`��
+
CRA STAM
Estimated cost of improvein�8>nt't : $
1) .Attach: two color photos. of each project to be
performed.
Maslmuh :grain award:. - $ .
2) : Attach' Property A" is,r'M.
3); 'AttaC.. proof of payment of property titzes. -
Signritpre "r r . Date .
Packet Pg. 68
5.A.2
3299 Tamiami Trl E Ste 103
Naples F134112
www.bayshorecra.com
Bayshore Gateway Triangle CRA j Commercial Buildina improvemoni Grant Informae:^:
Project Summar &L Evaluation (attach additional sheets as necessary)
Project Summar[Grantee
escribe the improvements made. ._c
I. t��-=ice 1 cic� C:X t : � 1-i �J G- � � �t � c�a ri►+: 1=� �v C� � �S
`t �_ �'�c»� �c:� t�.��.. a�t:,l�1►�Uc� 'FAN � ' 4: ;p,' .-�
List all vendors / contractors providing materials or services for this project with contact information.
Vendor / Service Provider
Phone Number or Address or Website
C, '7 VZ.
a.
Grantee Signature Date
Grantee Signature Date
CRA Staff. Color photos of completed project from site visit must be attached to this report.
E
M
0
m
i
O
N
Q
E
a
0
m
a�
0
J
d
a�
CU
C9
a�
L
0
M
m
r
Q
Packet Pg. 69
5.A.2
A� �) VLGMtiY��f. iw �%,pOm
Ba!yysh000rr/e Gateway CCTriangle CRA
j Applicant Commitment of Resources
I / we, ,Ci' owner(s) / tenant(s) of the
commercial property located at 7j.-zz^ "W4 *., e�ttPsj , have the funding and all other
capability necessary to begin the site improvements listed above and have the ability to complete all
improvements within one year of the approval of the improvement grant by the Collier County
Community Redevelopment Agency. I / we further affirm that payment for all work on approved
improvements will come from accounts in my / our name(s) or the name(s) of entities registered in
the State of Florida which I / we have incorporated or otherwise registered with the state (verification
is required). Payment for improvements by from persons or entities not a party to this Grant
Application is grounds for disqualification.
Signature of Tenant (if leased)
Signature of Tenant (if leased)
(if jointly leased)
�y1
Signature of Owner
Signature of Owner
(if jointly owned)
3299 Tamiami Trail E Suite 103
Naples F134112
www.bayshorecra.com
Date
Date
t,T �-� � - 7t
Date
Date
Packet Pg. 70
5.A.2
-1. _ .. � Ord , • ,..- �rro•,i'c ■ ■� o
YfR,J�WJ,•1fYYI.�.IV MMS/A
eo
CD
0
®
a-
V
U
LL (6
(IJ dJ
O
4-1
V) aj
m
ro Q
� QJ
a
® II
Cil "1:5
O
N 0
L
0
m
0
(n
a
a�
o
0
0
0
J
d
H
3
a�
r
d
�m
W
CD
LO
N
Packet Pg. 71
5.A.2
DO
,o
Ui�.irdr
/7
M
L.Lo
cnLL
4-J
M
®
Q-
Cil
CL
Packet Pg. 72
5.A.2
Bayshore Gateway Triangle CRA •Bayshore Beautification MSTU
Haldeman Creek MSTU
June 7, 2021
Bayshore Gateway Triangle CRA
Commercial Building Improvement Grant (CBIG)
Applicant:
Southern Region Development, LLC
C/O John Casey — Property Owner
2447 Breakwater Way
Naples Florida, 34112
Project location:
Sunbelt Facility
2600 Davis Boulevard
Naples Florida 34104
Project Scope:
A new rental facility is being built at 2600 Davis Boulevard; the property currently has a chain
link fence that is in poor condition. The property owner would like to install a new PermaWall
Stone Finish fence to replace the existing chain -link fence. The second quotes are for 7' Series A
3 channel black aluminum municipal grade (3) 5' walk gates, (2) Cantilever gates (24' and 16').
Estimates: 1. Fence 2. Gates
IA — Coastal Concrete Products, Port Charlotte Florida $46,200.00 (lowest bidder)
113 — Permacast, Bradenton, Florida $60,728.00
2A —Arc Tech Construction Svcs, LLC $36,735.00 (lowest bidder)
2B — Louis Morrello Construction, Inc.dba RS Construction $38,560.00
Lowest Bid Total $82,935.00
CRA contribution 50% or a Max of $30,000.00 CRA contribution for this application $30,000
Offices: 3299 Tamiami Trail E suite 103Naples, Florida 34112
Phone:239-252-8844
Online: www.BGTCRA.com
Packet Pg. 73
5.A.2
IA- CBIG Grant -Southern Region Developrnent, LLC- Property location 2600 Davis BLVD. Naples Florida
L
( Lowest Bidder) M
0
m
0
y
t�asrot Proposal but
ulrcrete
Coastal Concrete Products, LLC a
CL
Fort Myers, FL33912 Fax(239)334.1399
0
CGC111510460
;
N
O
lY
To: RS Construction of SW Florida Phone: 041-970-8490 Fax:
V
0
J
Address: 1225 Tamlaml Tr Suite AS Job Name: Sunbelt Attn: Ray Smith
d
I �
oity, state, Zip Code: Port Charlotte, FL Job Location: Naples
33953
Data of Plans: 5/21/20 Job Phone: Date: 5/8/2021
to
3
r
ro
C9
`o
Fence%
• Labor and material to Install 600 linear feet of 7' tall precast stackable concrete fence.
N
• Color to be standard light brown
to
• Permitting by Coastal Concrete Products, LLC
m
• Fence to be manufactured and Installed as per engineered drawings.
ti
• Price Is based on normal digging conditions
• Price is based on 150 mph wind zone exposure B
LON
Not Included
✓ Coastal Concrete Products, LLC. assumes no liability for underground utilities.
✓ Clearing, grading or fill to proper elevations.
✓ Survey If necessary by others.
✓ Rock excavation If necessary.
Owner/SmIlder Is Resnonslbta for the following:
✓ To Inspect materials for proper color, shape prior to Installation
✓ All underground utilities, sprinkler pipes, electrical eleeving eto.
✓ Dumpeler provided on site.
✓ Staked Location of well
WOOD LOOK $46,000. STONP LOOK$40,200.
260% Deposit required prior to manufacture of material
This prok2jgUbject to change after 30 Days
Sales Person: Tim Wlnschel
Packet Pg. 74
5.A.2
License Application Status
C36259
In order to view fees or view conditions, You need to he signed in.
Note: You can collapse and expand individual sections by clicking the header of the section you wish to collapse/expand.
_ . License Application Summary
Application Number:
C36259
Business Name:
COASTAL CONCRETE PRODUCTS, LLC
License Type:
Contractor
Application Status:
Active
Description of Business:
All Certificates from CDPlus: 36259
Mailing Address:
7742 ALICO RD
FORT MYERS FL 33912
Cwa Ikup@coa stalconcreteprodu cts, corn
— � Portal Licensee Status Details
Licensee Details: COASTAL CONCRETE PRODUCTS, LLC, Address: 7742 ALICO RD, Phone:
(239) 263-9700, State Reg #'s CGC1519460, Licensee # C36259
— � Issuances
Type >k Date Issued Date Expires Status Number
GENERAL CONTR.-CERTIFIED 09/10/2020 08/31/2022 1Active 36259
GENERAL CONTR.-CERTIFIED 09/18/2018 08/31/2020 Expired 36259
.Insurance
Producer Type W.,
Policy Effective Date Expiry Date Limit
GULFSHORE Worker's WC675866500 11/17/2014 11/17/2021
INSURANCE, INC Compensation
GULFSHORE General Liability GL00743477702 11/17/2014 11/17/2021 $2,000,000.00
INSURANCE, INC
DAVID E TORRES Worker's Comp (QUALIFIER) 12/16/2014 12/16/2020
Exemption
Packet Pg. 75
5.A.2
I B- CBIG Grant -Southern Region Development, LLC- Property location 2600 Davis BLVD. Naples Florida
( Not Used)
7ho takest dalivot), t: intalkition of Anualra :v ttcst IM.7Ds.
State Lkense #: CDC 1266823
Project Name: Sunbelt
Project 0: 2782
Permacast Walls Contact Information
Sales/PM:
Nick Solomon
Email:
nick®permacastwalis.com
Phone:
(888) 977-9255
Mobile:
+17274580018
Job Site Address if. Main Contact
Job Site Street: 2600 Davis Blvd
Job Site City. Naples
Job Site State: FL
Job Site Zip Code: 34104
Billing Information
Quotes Number: 00000850
Expiration Date: May 10, 2021
Sales Manager: Steven Hatcher
Email: Steven@permacastwalls.com
Phone: (888) 977-9255
Mobile: +18137204720
Contact Name: Ray Smith
Phone: (941) 628-6407
Email: mbrsconst@gmail.com
BIII To Name: RS Developement
BIII To Address: 1225 Tamlami Trail, Port Charlotte, FL 33953
Description: Furnish and Install 6041f of up to 8' 2.0 PermaWall Sand
uota Line Items
Product Name
Line Item Description
Quantity
Sales
Total Price
Price
PermaWall 2.0 - 8ft
Furnish & Install 8111 PermaWall 2.0 (20' O.C.) Stone Finish
604LF
$88.00
$53,152.00
- Sand
Initial Permit
Processing fee and actual permit fees up to $1000 any
1
$1,500.00
$1,500.00
Running Fee
additional fees paid by owner at cost via CO.
Standard Paint -
Permacast Specified Sherwin Williams Flex Lox Paint
604LF
$9.00
$5,436.00
One Color
Cap - 8.5x14 -
Decorative Column Cap
32
$20.00
$040.00
Deco
Totals
Grand Total: $60,728.00
Wind Load Exposure
Per LF Base Price Is based on*: 1160 13
o Should actual rating be determined higher than estimated, buyer is responsible for associated cost
difference.
www. aermacastwal Is.com
6015 21 st St. E, Bradenton, Florida 34203 * (941) 234-8879 Phone
Packet Pg. 76
5.A.2
A"'n f::�1
License Application Status
C33260
In order to view fees or view conditions, you need to be signed in.
Note: You can collapse and expand individual sections by clicking the header of the sedton you wish to collapse/expand.
— License Application Summary
Application Number:
C33260
Business Name:
PERMACAST LLC
License Type:
Contractor
Application Status:
Active
Description of Business:
All Certificates from CDPlus: 33260 - 4/15/2020: See Comments
Mailing Address:
6015 21ST STREET E
BRADENTON FL 34203
Ca rlosCsl permacastw ills. corn
_ Portal Licensee Status Details
Licensee Detalls:
Issuances
PERMACAST LI.C, Address:6015 21ST STREET E, Phone:(941) 234-8879,
State Reg #'s CBC1256823, Licensee # C33260
_
Type
Date Issued
Date Expires
Status
Number
BUILDING CONTR.-CERTIFIED
01/29/2021
08/31/2022
(Active 1332b0
BUILDING CONTR.-CERTIFIED
04/15/2020
08/31/2020
( Expired
33260
_
Insurance
Producer
Type
_ ....._....._...._._._..._.._._..__—.._.._.._......,---.._-_-.----..___.....___—_
I Policy
Effective Date Expiry Date
Limit
GIFFORD-HEIDEN INS
Worker's
196-49962
01/08/2020 01/08/2022
- NG/VG
Compensation
GIFFORD-HEIDEN INS
General Liability
20681471
03/28/2020 03/28/2021
$3,000,000.00
- NG/VG
Packet Pg. 77
5.A.2
FENCE DESIGNS
B Y A R C T E C H
PROPOSAL FROM
ARC TECH CONSTRUCTION SERVICES, LLC
CGC1516497
7742 Alico RD
Fort Myers, FL 33912
Tel: (239) 263-1188
Fax: (239) 263-1058
To: RS Construction of SW Florida Phone: 941-979-8490 Fax:
Address: 1225 Tamiami Tr Suite 8A Job Name: Sunbelt Attn: Ray Smith
City, State, Zip Code: Port Charlotte, FL Job Location: Naples
33953
Date of Plans: Job Phone: Date: 5/24/2021
'► Labor and material to install 7' Series A 3 channel aluminum black Municipal grade fence to include
y► 24' and 16' cantilever gates and three (3) 5' walk gates with lock boxes (locks by others)
Permit by Arc Tech Construction Services, LLC
Price is based on normal digging conditions
Not Included
✓ Arc Tech Construction Services, LLC. assumes no liability for underground utilities.
✓ Clearing, grading or fill to proper elevations.
✓ Survey and location markings by others.
Owner/Builder is Responsible for the following:
✓ To inspect materials for proper color, shape prior to installation
✓ All underground utilities, sprinkler pipes, electrical sleeving etc.
✓ Staked Location of fence -
BID TOTAL This Proposal subject to change after 30 Days
$36,735.00
Sales Person: Tim Winschel
Acceptance of Proposal I agree to the above prices, specifications and conditions. I authorize
you to begin work as scheduled. I agree to full payment on completion of the work.
Signature
Officer Signature / Title
Print Name:
Date:
Packet Pg. 78
5.A.2
License Application Status
LCC20110003177
In order to view fees or view conditions, you need to be signed In.
Note: You can collapse and expand Individual sections by clicking the header of the section you wish to collapse/expand.
. License Application Summary
Application Number:
LCC20110003177
Business Name:
ARC TECH CONSTRUCTION SERVICES, LLC
License Type:
Contractor
Application Status:
Active
Description of Business:
Mailing Address:
7742 ALICO ROAD
FORT MYERS FL 33912
Cwalkup@coastalconcreteproducts.com
— . Portal Licensee Status Details
Licensee Details: ARC TECH CONSTRUCTION SERVICES, LLC, Address:7742 ALICO ROAD,
Phone:(239) 263-1188, State Reg #'s CGC1516497, Licensee #
LCC20110003177
. Issuances
Type
GENERAL CONTR: CERTIFIED
GENERAL CONTR: CERTIFIED
Insurance
Producer
GULFSHORE
(INSURANCE-SWFL
GULFSHORE
INSURANCE-SWFL
DAVID E TORRES
Date Issued Date Expires
Status
Number
12/01/2020 08/31/2022
Active
1201100001550
11/30/2018 108/31/2020
Expired
1201100001550
Type Policy Effective Date Expiry Date Limit§
General Liability I ENP0544908 1 07/15/2020 107/15/2021 I $2,000,000.00
Worker's TWC3895852 1 07/15/2020 07/15/2021
Compensation
Street Address: Exclusions
Worker's Comp I QUALIFIER — —I 12/15/20161/24/2021 l —
Exemption J IL _IL
Packet Pg. 79
5.A.2
' 206 Fletcher St.
fort Charlotte. FI 33952
4 one #.: (941)276-9750
3C1256593
.1,9ovNorrpello affurvemov
in
°F Construction of SW Florida
..__=-amiami Trail A-8
? Charlotte. I'L 33952
iE: Sunbelt Rental Naples Fencing Quote
"one of work:
-installation of a 7' Series A 3 channel black aluminum Municinal grade fencing
to include (2) cantilever gates (24' and 161 and (3) 5' walk gates.
-APrmit to be provided by contractor.
Please note:
W alterations or deviations from the above soecifications involving extra costs will be executed
oniv upon written orders and will become an extra charge, over and above the estimate /
proposal. This estimate / proposal may be withdrawn by us if not accepted within 30 days.
'Please Initial
Acrentance of Proposal / Estimate: The above prices, specifications and conditions are
". _ = actorv. ana the deposit is raid, this is herebv accepted as a legal and binding contract. You
N nuts Morrello Construction. Inc.) are authorized to do the work specified. Pavment will be
made as outlined below.
**NO WORK WILL BE PERFORMED WITHOUT AN AUTHORIZED SIGNATURE**
TO TALJOB COST: S38.560.00
20% DEPOSIT: S7.712.00
O1!1' UPON COMPLETION: 530.848.00
;rr..eoted Bv:
'7 nn.ature of Acceotance Date Louis Morrello. Manager Date
Packet Pg. 80
5.A.2
Ron DeSantis, Governor
STATE OF FLORIDA
Halsey Beshears, Secretary
dIFIQdda
Dpr
DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
CONSTRUCTION INDUSTRY LICENSING BOARD
THE BUILDING CONTRACTOR HEREIN IS CERTIFIED UNDER THE
PROVISIONS OF CHAPTER 489, FLORIDA STATUTES
MORRELLO, LOUIS ANTHONY
R.S. DEVELOPMENT OF SOUTH WEST FLORIDA L.L.C.
1225 TAMIAMI TRAIL UNIT A 8
j`PORT, �CHARLOTTE FL •33953
LICENSE NUMBER: CBC1256593
EXPIRATION DATE: AUGUST 31, 2022
Always verify licenses online at MyFloridaLicense.com
Do not alter this document in any form.
This is your license. It is unlawful for anyone other than the licensee to use this document.
Packet Pg. 81
5.A.2
Collier County Property Appraiser
Property Summary
Site 2600
Parcel No 70820320000 Address DAVIS Site City NAPLES
*Disclaimer BLVD
Name / Address !SOUTHERN REGION DEV LLC
2447 BREAKWATER WAY #8-201
Site Zone
*Note 34112
City NAPLES
State FL Zip 34112
j
Map No. Strap No.
Section Township Range Acres
*Estimated
5A11 601900 255A11
11 50 25
0.81 ,
Leal ROCK CREEK PINES UNIT
g
2 LOTS 2S + 26 + FOLL DESC, E 85FT OF W 339.4FT OF
ILOT 29, NGTCLF 2
Mill@ge Area O : 112
Millage Rates O *Calculations
Sub./Condo 601900 - ROCK CREEK PINES UNIT 2 School Other
Total
Use Code O 11 - STORES, ONE STORY
5.016 6.2924
11.3084
Latest Sales History
2020 Certified Tax Roll
(Not all Sales are listed due to Confidentiality)
(Subject to Change)
Date j Book -Page Amount
Land Value
$ 638,151 1
05/11/17 5393-1344
$ 0
(+) Improved Value
$ 271,2561
05/11/17 5393-1342
$ 0
(_) Market Value
$ 909,4071
04/23/03 3272-2731
$ 0
(_) 10% Cap
$ 28,097 1
04/23/03 3272-2729
$ 0
(_) Assessed Value
$ 881,3101
04/23/03 � 3272-2727
3272-2725
$ 0
$ 0
(_) School Taxable Value
$ 909,407'
04/23/03
04/23/03 3272-2723
$ 0
(_) Taxable Value
$ 881,310
04/23/74 586-1425
$ 0
If all Values shown above equal 0 this parcel was created after the
Final Tax Roll
Packet Pg. 82
5.A.2
------------..-, • ••••••••, •,. •-... • �....,vn. . unw anu ,vvn-n4 vdWltllll ASSBS6lrlen[S
If Paid By
j Nov 30, 2020
_ Please PayY
Parcel Number _
__$0.00
Ledal Description -�! - '�— MIII Code Escrow Code
708203200,00
I ROCK CREEK PINES UNIT 2 LOTS
25 + 26 + FOLL DESC, E 85FT 112
_ - �
I OF W 33 AFT OF LOT 29,
NGT1
SOUTHERN REGION DEV LLC
2447 BREAKWATER WAY #8-201
Pay In U.S. Funds Drawn on U.S. Bank To: NAPLES, FL 34112
Collier County Tax Collector
3291 E. Tamiami Trail
Naples, FL 34112-5758
POST DATED CHECKS ARE NOT ACCEPTED AND WILL HE RETURNED
_
Visit our website: www.colllortaxoollector.com
��-
Assessed Value
_
District MIII Rate Assessed Value Exempt Amt Taxable Value Tax Amount
881,310
GENERAL FUND 3.5645 881,310 0 881.310 3,141.43
WATER MANAGEMENT FUND-SOUTF 0.1103 881,310 0 881,310 97.21
Exemptions
BIG CYPRESS BASIN 0.1152 881,310 0 881,310 101.53
SCHOOL BOARD - STATE LAW 2.7680 909,407 0 909,407 2,517.24
SCHOOL BOARD - LOCAL BOARD 2.2480 909,407 0 909,407 2,044.35
COLLIER MOSQUITO CONTROL 0.1662 881,310 0 881,310 146.47
GREATER NAPLES FIRE RESCUE DIE 1.5000 881,310 0 881,310 1,321.97
UNINCORP GEN - MSTD 0.8069 881,310 0 881,310 711.13
C.G. WATER POLLUTION CTRL PGM 0.0293 881,310 0 881,310 25.82
Millage Total 11.3084 Total Ad Valorem $10,107.15
Pay your current taxes online at:
http:i/www.colllertaxcoitector.coml
Non -Ad Valorem District Type of Assessment Amount
Non -Ad Valorem Total $0.00
See reverse side for important information
Combined Ad Valorem and Non -Ad Valorem Total $10,107.15
(Detach and Return .vIth your r ayment)
1 2020 Paid Collier County Notice of Ad Valorem Taxes and Non -Ad Valorem Assessments
If Paid By
Please Pay
Nov 30, 2020
$0.00
Parcel Number MIII Code Escrow Code
70820320000
112
ROCK CREEK PINES UNIT 2 LOTS
25 + 26 + FOLL DESC, E 85FT
OF W 339AFT OF LOT 29,
NGTCLF 2
SOUTHERN REGION DEV LLC
2447 BREAKWATER WAY #8-201
NAPLES, FL 34112
11/18(2020
Amount Paid to Date: 9702,66
Receipt # 130-21-00261297
Paid By SOUTHERN REGION DEV LLC
Please
Retalr
this
portlol
for yol
record
Packet Pg. 83
5.A.2
COLLIER COUNTY
TAX COLLECTOR
HILL
Srar:_h > i�<<<ninl. Stim�u ry > BIII Details
Business Tax Account #743447
SUNBELT RENTALS, INC.
Current owner:
SUNBELT RENTALS, INC.
Current business address:
2600 DAVIS BLVD
QQ 1 1 1 , D 't.l;I"
Current business phone:
774-7117
.$►
Got hilts by email
2021 Details
Account number: 743447
Business start date: 07/01/1974
Physical business location: Collier County
Business address: SUNBELT RENTALS, INC.
2600 DAVIS BLVD
Business phone: 774-7117
Mailing address: SUNBELT RENTALS, INC.
ATTN: LICENSING
2341 DEERFIELD DR
FORT MILL, SC 29715
Owners(s): SUNBELT RENTALS, INC.
2341 DEERFIELD DR
FORT MILL, SC 29715
RECEIPTS AND OCCUPATIONS
RECEIPT 743447
PUBLIC SERVICES $0.00
EQUIPMENT RENTAL SERVICE
RECEIPT 760564
RETAIL SALES $0.00
RETAIL SALES
Packet Pg. 84
5.A.2
PLORIDA amwi NSTA,LL DIVISION of CORPORATION:;
rNT 0
Department of Slate / Divisian of Corporations / Search Records / $(arch by n ity Name /
Packet Pg. 85
5.A.2
Report Year
Filed Date
2019
03/28/2019
2020
01 /13/2020
2021
01 /12/2021
Document Imagel
01/12/2021 —ANNUAL REPORT
01/13/2020 —ANNUAL REPORT
03128/2019 — ANNUAL REPORT
01/18/2018 — ANNUAL REPORT
03/27/2017 -- Florida Limited Liabiiity.
View image in PDF foment
View image in PDF format
View image in PDF formal
View image in PDF formal
View image in PDF format
Packet Pg. 86
5.A.2
f�
6i9
IQ)
LL
�
LO
W
Packet Pg. 87
5.A.2
10c2 -B4t,711V
Bayshore Gateway Triangle CRA •Bayshore Beautification MSTU -a
Haldeman Creek MSTU to
L
m
STAFF REPORT Item 5b
0
A
TO: BGTCRA Local Redevelopment Advisory Board
a
FROM: Gregory J. Oravec, CRA Director
DATE: June 27, 2023
SUBJECT: 17-AcresBoardwalk/Connection to Sugden Park/Expenditure of CRA Funds outside of the
Community Redevelopment Area
Request/Issue: Authorization to spend up to $4,000 in CRA funds outside of the Community Redevelopment Area
for application fees payable to the Collier County Growth Management Department for the connection of the 17-
Acres/Boardwalk to Sugden Regional Park
Background and Analysis:
The much -anticipated Boardwalk Project will connect the CRA's 17-acre parcel, Bayshore, and the
greater Community Redevelopment Area to Sugden Regional Park. The Boardwalk is expected to become an
incredible recreational destination and will also create safe, beautiful pedestrian and bicycle linkages,
facilitate community events, invite additional desirable redevelopment, and allow more citizens to better access
the gem that is Sugden Regional Park.
Through its consultants, the CRA is currently engaged in the design and permitting of the subject project, and the
current constraining items of work include a Site Development Plan (SDP) Application and Site Development Plan
Insubstantial Change (SDPI) Application. Normally, the expenditures associated with these routine processes would
be handled administratively. However, in this case, there are special circumstances that warrant a recommendation
from the Advisory Board and require action by the Board of County Commissioners and Board of County
Commissioners acting as the CRA Board.
Even though the subject project will be of significant benefit to the Community Redevelopment Area, there are no
less than 25 references to "Sugden" in the adopted Community Redevelopment Plan, and the Community
Redevelopment Plan explicitly identifies "connections between Sugden Regional Park and the CRA" in multiple
sections, including Section 5.0.5, entitled "Focus of Redevelopment," Sugden Park is not technically located within
the Community Redevelopment Area. Therefore, a portion of the Boardwalk Project, that portion between the CRA
boundary line and the end of the Boardwalk, is located outside of the CRA and will require the CRA to spend money
outside of its boundaries.
In Florida, with few exceptions, a community redevelopment agency should only spend its tax increment revenue
within the boundaries of the community redevelopment area; and the County Attorney's Office has advised staff that
the subject item should be approved by the Board of County Commissioners and the Board of County Commissioners
acting in its capacity as the CRA Board.
Recommendation:
Given that the "connection" of the subject project is specifically identified by the Community Redevelopment Plan,
physically contiguous to the Community Redevelopment Area, and will benefit the Community Redevelopment
Area, staff recommends approval of the request to spend up to $4,000 in CRA funds outside of the Community
Redevelopment Area for application fees payable to the Collier County Growth Management Department.
Attachments:
1. GMD Invoice SDPI
2. Redevelopment Plan 5.0.5 Item 6
Packet Pg. 88
5.A.2
Collier County Payment Slip (PL)
Date:
May 18 2023
Contact:
Joel Blikstad
3510 Kraft RD
Unit 200
Naples, FL 34105
Project Name:
Ba shore Drive Foot Bridge SDPI
Project Number:
PL20230009235
FEES:
Fee Descri tion I Reference Number IAmount
Site Development Plan Insubstantial Change
PL20230009235
$400.00
PL20230009235
$100.00
Fire Code Review - Insubstantial Change to Site Plan
PL20230009235
$600.00
Plan Sheets fee SDPI ICP SBRI
PL20230009235
$649.74
Construction Review Fee
PL20230009235
$1,949.23
Construction Inspection Fee
Total:
$3,698.97
rre-App ureaits:
Item Iyp-e Balance
To pay online use the following link:
https:L/cvportal.colliercountyfl.gov/CityViewWeb/
Packet Pg. 89
CUTIVE SUMMARY
).5 Focus of Redevelopment.
Following provides a focus of redevelopment for
i Character Area based on the specific
acteristics described in Map 5-ES-2 and the most
(ant redevelopment strategies,
fini Triangle/Davis
Jrban-style mixed use commercial
-edevelopment, including capitalization on the
Vini Triangle as a catalyst development site and
Jrban-style parking solutions
Sark development at retention pond site
-omplete Streets design and commercial
-edevelopment along Linwood Ave and other
iearby commercial roadways; pedestrian scale
street design between Mini Triangle, Linwood
We, and the proposed retention pond park
mproved access to Mini Triangle development
rom US 41, Davis Blvd, and Linwood Ave
viulti-modal connectivity:
• Across Davis Blvd
• Between Mini Triangle, Linwood Ave,
proposed retention pond park, and
eastern Triangle neighborhood
• To Downtown Naples potentially via Davis
Blvd, US 41, and Gordon River Bridge
improvements
additional infrastructure improvements: sanitary
,ewers, electrical, stormwater
5.A.2
L
• Infill development on vacant residential lots
�./0
W
i>-,
• Flooding and drainage on neighborhood streets
0
• Complete Street improvements along
Q
Shadowlawn Drive
c
E
3. Airport Pulling
a
• Transitions between residential neighborhoods
and commercial development
• Eventual street enhancements, particularly
0
connectivity across Airport Pulling Rd
• Commercial facade improvements
a�
•L
4. Tamiami
• Connectivity to Downtown Naples via US 41
• Redevelopment of Courthouse Shadows
• Tenant opportunity and site improvements for
0
y
walkable design at Gulfgate Plaza
m
5. Windstar
ti
• Complete Streets and MSTU improvements along
rn
N
major community roadways, including Bayshore
ch
Drive, Thomasson Drive, and Hamilton Avenue
N
N
rn
• Access to Bayview Park N
.e%
6. North Bayshore
• Corridor commercial development along Bayshore
Drive, including Haldeman Creek Entertainment
Center near Creek and creative parking solutions
• Larger redevelopment opportunities of 17-Acre
Site and Del's 24 property
• Arts and culture -oriented development
hadowlawn • Transitional elements between corridor
tesidential structural enhancement and upgrades commercial and residential areas along Bayshore
voidance of incompatible uses
Drive and Thomasson Drive
7ansiiional elements between different uses
Development of vacant residential lots
S-E-9
Bayshore Gateway Triangle CRA Area Plan —Draft March 2019
Packet Pg. 90
EXECUTIVE SUMMARY
5,n
• Complete Street design along Bayshore Drive and
Thomasson Drive, including Bayshore Drive/
Thomasson Drive roundabout
• Neighborhood Complete Streets and trails
• Connections between Sugden Regional Park and
CRA area
Is Water main and fire suppression upgrades
• Flooding and drainage on neighborhood streets
7. South Bayshore
• Mobile home and single-family home residential
improvements, upgrades, affordability
• Development of vacant residential lots
• Access to Bayview Park
• Connections between CRA and uses to the east,
including East Naples Community Park
• Wetland, flooding, and site preparation
considerations for development
• Roadway improvements to meet County
engineering standards
• Neighborhood Complete Streets
5.0.6 Funding, Projects, &
Initiatives
The Redevelopment Area Plan also provides a
comprehensive list of capital projects and non -capital
initiatives in support of the vision with a prioritization
plan and recommendation for allocated funding .
Table 5-ES-1 summarizes projected revenues for
various funding sources operating in the CRA area,
including Municipal Service Taxing Units (MSTUs) that
are funding sources independent of Tax Increment
Finance (TIF).
This Plan does not obligate any funding to any projects
listed. This Plan provides a guide and list of both
capital and non -capital projects that tax increment
revenues can fund if approved by the CRA and
allocated through the standard operating and
procurement guidelines adopted by the Collier County
Board of Commissioners. The Plan sets a framework
based on current conditions but also allows for
flexibility in the phasing of projects based on funding
opportunities and community priorities identified in
annual work plans and capital improvement project
lists.
Figures 5-ES-2 through 5-ES-4 summarize the funding
breakdown by timeframe and type of project/
initiative. Note that non -capital projects include
studies, plans, and grant programs. Table S-ES-2
provides an overall summary of TIF revenues and costs
with surpluses and shortfalls noted for each time
period (note that some projects are programmed at a
deficit because other funding partners or sources are
anticipated). Table S--ES-3 shows CRA project costs
that may also be eligible for Bayshore Beautification
MSTU funds, indicating the potential benefit from
MSTU coordination.
Bayshore Gateway Triangle CRA Area Plan —Draft March 2019
r
a
5-E-10 �
Packet Pg. 91
]CI4
u
m
E
D
+1
mBue|J1 AE mmeeao4s eg:L 6 Z £ 0-6- 48)I3e depueBVBmmam m!Oo dS VND198: ewlV n¥
$
0
�
�
0
�
�
E
0
/
0
�
E
&
�
§
/
e
2
m
�
0
U
a)
?
<
m
0
�
_
_
0
®
\
•-
m
0
$
a)
z
ƒ
o
4-1
m
q
q
a)\
E
2
u
\
.\
0
-0
ƒ
/
�
q
-0
o
6
/
/
±I
0
£
2
_
�
&
4-
O
_
e
4
%
«
D
L
LU
�
cq
24
ro
/
%
q
o
N
w
(
-0
/
0
&
2
'
=
�
2
�
E
V,
0
'
I
=
a)
\
0
55
3
0
%
o
=
u�,A
0
O
=
/
.%
k