Backup Documents 01/12/2021 Item #16A27 20-7678 AgnoliBarberBrundage_Contract (4)PROFESSIONAL SERVICES AGREEMENT
Contract # 20-7678
for
Solana Road Stormwater Improvements Design Services
THIS AGREEMENT is made and entered into this (O day of 14Q4Qdy, 20 20 by
and between the Board of County Commissioners for Collier County, Florida, a political
subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and
Agnoli, Barber & Brundage, Inc. authorized
to do business in the State of Florida, whose business address is
2770 South Horseshoe Drive, Suite 7, Naples, FL 34104 hereinafter
referred to as the "CONSULTANT" and/or "CONTRACTOR").
WITNESSETH:
WHEREAS, the COUNTY desires to obtain the professional services of the CONSULTANT
concerning Solana Road Stormwater Improvements Design Services
hereinafter referred to as the "Project"), said services in accordance with the provisions of Section
287.055, Florida Statutes being more fully described in Schedule A, "Scope of Services", which
is attached hereto and incorporated herein; and
WHEREAS, the CONSULTANT has submitted a proposal for provision of those services;
and
WHEREAS, the CONSULTANT represents that it has expertise in the type of professional
services that will be required for the Project.
NOW, THEREFORE, in consideration of the mutual covenants and provisions contained
herein, the parties hereto agree as follows:
ARTICLE ONE
CONSULTANT'S RESPONSIBILITY
1.1. CONSULTANT shall provide to COUNTY professional services in all phases of the Project
to which this Agreement applies.
1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the
Scope of Services described in detail in Schedule A. The total compensation to be paid
CONSULTANT by the COUNTY for all Basic Services is set forth in Article Five and Schedule B,
Basis of Compensation", which is attached hereto and incorporated herein.
1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement
all such licenses as are required to do business in the State of Florida and in Collier County,
Page 1 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
C"r )
Florida, including, but not limited to, all licenses required by the respective state boards and other
governmental agencies responsible for regulating and licensing the professional services to be
provided and performed by the CONSULTANT pursuant to this Agreement.
1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a
professional service which, under Florida Statutes, requires a license, certificate of authorization
or other form of legal entitlement to practice such services, it shall employ and/or retain only
qualified personnel to provide such services to the COUNTY.
1.5. CONSULTANT designates Dominick J. Amico, P.E.a qualified licensed
professional to serve as the CONSULTANT's project coordinator (hereinafter referred to as the
Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of
the CONSULTANT with respect to directing, coordinating and administering all aspects of the
services to be provided and performed under this Agreement. Further, the Project Coordinator
has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating
to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever
time is required to satisfactorily manage the services to be provided and performed by the
CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from
the Project without the COUNTY's prior written approval, and if so removed must be immediately
replaced with a person acceptable to the COUNTY.
1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request
from the COUNTY to promptly remove and replace the Project Coordinator, or any other
personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors
or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT
to provide and perform services or work pursuant to the requirements of this Agreement, said
request may be made with or without cause. Any personnel so removed must be immediately
replaced with a person acceptable to the COUNTY.
1.7. The CONSULTANT represents to the COUNTY that it has expertise in the type of
professional services that will be performed pursuant to this Agreement and has extensive
experience with projects similar to the Project required hereunder. The CONSULTANT agrees
that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to
the COUNTY's review and approval and shall be in accordance with the generally accepted
standards of professional practice in the State of Florida, as well as in accordance with all
applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and
requirements of any governmental agencies, and the Florida Building Code where applicable,
which regulate or have jurisdiction over the Services to be provided and performed by
CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76
F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those
contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF
CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE
CUSTODIAN OF PUBLIC RECORDS AT:
Page 2 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
C80
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8999
The Contractor must specifically comply with the Florida Public Records Law to:
1. Keep and maintain public records required by the public agency to perform the
service.
2. Upon request from the public agency's custodian of public records, provide the
public agency with a copy of the requested records or allow the records to be
inspected or copied within a reasonable time at a cost that does not exceed the cost
provided in this chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for
the duration of the contract term and following completion of the contract if the
Contractor does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records
required by the public agency to perform the service. If the Contractor transfers all
public records to the public agency upon completion of the contract, the Contractor
shall destroy any duplicate public records that are exempt or confidential and
exempt from public records disclosure requirements. If the Contractor keeps and
maintains public records upon completion of the contract, the Contractor shall meet
all applicable requirements for retaining public records. All records stored
electronically must be provided to the public agency, upon request from the public
agency's custodian of public records, in a format that is compatible with the
information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally
terminate this Agreement immediately.
1.8. In the event of any conflicts in these requirements, the CONSULTANT shall notify the
COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY
regarding resolution of each such conflict. The COUNTYS approval of the design documents in
no way relieves CONSULTANT of its obligation to deliver complete and accurate documents
necessary for successful construction of the Project.
1.9. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount
for the following: Tasks not completed within the expressed time frame, including required
deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or
federal requirements and/or codes and ordinances applicable to CONSULTANT's performance
of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY
reserves the right to make sole determination regarding deductions. After notification of
deficiency, if the CONSULANT fails to correct the deficiency within the specified timeframe, these
funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge the
Page 3 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
C
CONSULTANT for services and/or items necessary to correct the deficiencies directly related to
the CONSULTANT's non-performance whether or not the COUNTY obtained substitute
performance.
1.10. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or
organization, without the COUNTY's prior written consent, or unless incident to the proper
performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or
legislative proceedings where such information has been properly subpoenaed, any non-public
information concerning the services to be rendered by CONSULTANT hereunder, and
CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to
comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt
written notice of any such subpoenas.
1.11. As directed by the COUNTY, all plans and drawings referencing a specific geographic area
must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in
the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should
either reference specific established Survey Monumentation, such as Certified Section Corners
Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real-
Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have
common naming conventions (i.e. right-of-way- ROW, centerlines - CL, edge-of-pavement- EOP,
etc.), and adhere to industry standard CAD specifications.
ARTICLE TWO
ADDITIONAL SERVICES OF CONSULTANT
2.1. If authorized in writing by the COUNTY through a Change Order or Amendment to this
Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types
listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional
Services shall be set forth in the Change Order or Amendment authorizing those Additional
Services. With respect to the individuals with authority to authorize Additional Services under this
Agreement, such authority will be as established in the COUNTY's Procurement Ordinance and
Procedures in effect at the time such services are authorized. These services will be paid for by
the COUNTY as indicated in Article Five and Schedule B. Except in an emergency endangering
life or property, any Additional Services must be approved in writing via a Change Order or an
Amendment to this Agreement prior to starting such services. The COUNTY will not be
responsible for the costs of Additional Services commenced without such express prior written
approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i)
a waiver of any claim by CONSULTANT for such Additional Services and (ii) an admission by
CONSULTANT that such Work is not additional but rather a part of the Basic Services required
of CONSULTANT hereunder. If the COUNTY determines that a change in the Agreement is
required because of the action taken by CONSULTANT in response to an emergency, an
Amendment shall be issued to document the consequences of the changes or variations, provided
that CONSULTANT has delivered written notice to the COUNTY of the emergency within forty-
eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure
to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT's right it
otherwise may have had to seek an adjustment to its compensation or time of performance under
this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic
Services, shall be Additional Services:
Page 4 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
0
2.2. Preparation of applications and supporting documents (except those already to be
furnished under this Agreement) for private or governmental grants, loans, bond issues or
advances in connection with the Project.
2.3. Services resulting from significant changes in the general scope, extent or character of the
Project or its design including, but not limited to, changes in size, complexity, the COUNTY's
schedule or character of construction; and revising studies, reports, design documents or Contract
Documents previously accepted by the COUNTY when such revisions are required by changes
in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably
anticipated prior to the preparation of such studies, reports or documents, or are due to any other
causes beyond CONSULTANT's control and fault.
2.4. Providing renderings or models for the COUNTY's use.
2.5. Investigations and studies involving detailed consideration of operations, maintenance and
overhead expenses; the preparation of feasibility studies, cash flow and economic evaluations,
rate schedules and appraisals; and evaluating processes available for licensing and assisting the
COUNTY in obtaining such process licensing.
2.6. Furnishing services of independent professional associates and consultants for other than
the Basic Services to be provided by CONSULTANT hereunder.
2.7. Services during travel outside of Collier and Lee Counties required of CONSULTANT and
directed by the COUNTY, other than visits to the Project site or the COUNTY's office.
2.8. Preparation of operating, maintenance and staffing manuals, except as otherwise provided
for herein.
2.9. Preparing to serve or serving as a CONSULTANT or witness for the COUNTY in any
litigation, or other legal or administrative proceeding, involving the Project (except for assistance
in consultations which are included as part of the Basic Services to be provided herein).
2.10. Additional services rendered by CONSULTANT in connection with the Project, not
otherwise provided for in this Agreement or not customarily furnished in Collier County as part of
the Basic Services in accordance with generally accepted professional practice.
ARTICLE THREE
THE COUNTY'S RESPONSIBILITIES
3.1. The COUNTY shall designate in writing a project manager to act as the COUNTY's
representative with respect to the services to be rendered under this Agreement (hereinafter
referred to as the "Project Manager"). The Project Manager shall have authority to transmit
instructions, receive information, interpret and define the COUNTY's policies and decisions with
respect to CONSULTANT's services for the Project. However, the Project Manager is not
authorized to issue any verbal or written orders or instructions to the CONSULTANT that would
have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever:
Page 5 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
1:
J
a. The scope of services to be provided and performed by the CONSULTANT hereunder;
b. The time the CONSULTANT is obligated to commence and complete all such services;
or
c. The amount of compensation the COUNTY is obligated or committed to pay the
CONSULTANT.
3.2. The Project Manager shall:
a. Review and make appropriate recommendations on all requests submitted by the
CONSULTANT for payment for services and work provided and performed in
accordance with this Agreement;
b. Provide all criteria and information requested by CONSULTANT as to the COUNTY 's
requirements for the Project, including design objectives and constraints, space,
capacity and performance requirements, flexibility and expandability, and any
budgetary limitations;
c. Upon request from CONSULTANT, assist CONSULTANT by placing at
CONSULTANT's disposal all available information in the COUNTY's possession
pertinent to the Project, including existing drawings, specifications, shop drawings,
product literature, previous reports and any other data relative to the Project;
d. Arrange for access to and make all provisions for CONSULTANT to enter the Project
site to perform the services to be provided by CONSULTANT under this Agreement;
and
e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the
COUNTY with respect to the services to be rendered by CONSULTANT hereunder.
ARTICLE FOUR
TIME
4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the
execution of this Agreement upon written Notice to Proceed from the COUNTY for all or any
designated portion of the Project and shall be performed and completed in accordance with the
Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of
the essence with respect to the performance of this Agreement.
4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its
services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due
to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of
government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or
lock-outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days
after commencement of such delay, stating the specific cause or causes thereof, or be deemed
to have waived any right which CONSULTANT may have had to request a time extension for that
specific delay.
4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of CONSULTANT's services from any cause whatsoever, including those for which the
COUNTY may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform
or give rise to any right to damages or additional compensation from the COUNTY.
CONSULTANT's sole remedy against the COUNTY will be the right to seek an extension of time
to its schedule provided, however, the granting of any such time extension shall not be a condition
Page 6 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall
expressly apply to claims for early completion, as well as claims based on late completion.
Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided
hereunder have been delayed for a total of 180 calendar days, CONSULTANT's compensation
shall be equitably adjusted, with respect to those services that have not yet been performed, to
reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such
delays.
4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the
services to be provided hereunder in a timely manner, in addition to any other rights or remedies
available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold
any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT
resumes performance of its obligations hereunder in such a manner so as to reasonably establish
to the COUNTY's satisfaction that the CONSULTANT's performance is or will shortly be back on
schedule.
4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue
performing Work under this Agreement or any payment issued by the COUNTY to CONSULTANT
be deemed a waiver of any right or claim the COUNTY may have against CONSULTANT for delay
or any other damages hereunder.
ARTICLE FIVE
COMPENSATION
5.1. Compensation and the manner of payment of such compensation by the COUNTY for
services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled
Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager,
or designee, reserves the right to utilize any of the following Price Methodologies:
Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are
transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no
hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction
of the COUNTY's Project Manager before payment for the fixed price contract is authorized.
Time and Materials: The COUNTY agrees to pay the contractor for the amount of labor
time spent by the CONSULTANT 's employees and subcontractors to perform the work (number
of hours times hourly rate), and for materials and equipment used in the project (cost of materials
plus the contractor's mark-up). This methodology is generally used in projects in which it is not
possible to accurately estimate the size of the project, or when it is expected that the project
requirements would most likely change. As a general business practice, these contracts include
back-up documentation of costs; invoices would include number of hours worked and billing rate
by position (and not company (or subcontractor) timekeeping or payroll records), material or
equipment invoices, and other reimbursable documentation for the project.
5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall
apply only to tasks procured under the Time and Materials pricing methodology specified in
paragraph 5.1 above. I I Grant Funded: The hourly rates as set forth and identified in Schedule
B, which is attached hereto, are for purposes of providing estimate(s), as required by the grantor
agency.
Page 7 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
ill
ARTICLE SIX
THE OWNERSHIP OF DOCUMENTS
6.1. Upon the completion or termination of this Agreement, as directed by the COUNTY,
CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents,
drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations,
reports and other technical data, other than working papers, prepared or developed by or for
CONSULTANT under this Agreement("Project Documents"). The COUNTY shall specify whether
the originals or copies of such Project Documents are to be delivered by CONSULTANT.
CONSULTANT shall be solely responsible for all costs associated with delivering to the COUNTY
the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project
Documents for its files and internal use.
6.2. Notwithstanding anything in this Agreement to the contrary and without requiring the
COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a
nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use on this
Project. CONSULTANT warrants to the COUNTY that it has full right and authority to grant this
license to the COUNTY. Further, CONSULTANT consents to the COUNTY's use of the Project
Documents to complete the Project following CONSULTANT's termination for any reason or to
perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT
also acknowledges the COUNTY may be making Project Documents available for review and
information to various third parties and hereby consents to such use by the COUNTY.
ARTICLE SEVEN
MAINTENANCE OF RECORDS
7.1. CONSULTANT will keep adequate records and supporting documentation which concern
or reflect its services hereunder. The records and documentation will be retained by
CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement
or (b) the date the Project is completed, whichever is later, or such later date as may be required
by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY, shall,
free of charge, have the right to audit, inspect and copy all such records and documentation as
often as they deem necessary during the period of this Agreement and during the five (5) year
period noted above, or such later date as may be required by law; provided, however, such activity
shall be conducted only during normal business hours.
ARTICLE EIGHT
INDEMNIFICATION
8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and hold
harmless the COUNTY, its officers and employees from any and all liabilities, damages, losses
and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the
extent caused by the negligence, recklessness, or intentionally wrongful conduct of
CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this
Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce
any other rights or remedies which otherwise may be available to an indemnified party or person
described in this paragraph 8.1.
Page 8 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
t C)
8.2. To the extent that the Agreement that the work pertains to a "Professional Services
Contract" as defined in Section 725.08(3), Florida Statutes, and the CONSULTANT is a "Design
Professional" as defined in Section 725.08(4), Florida Statutes, the indemnification provided
herein shall be limited as provided in Sections 725.08(1) & (2), Florida Statutes.
ARTICLE NINE
INSURANCE
9.1. CONSULTANT shall obtain and carry, at all times during its performance under the
Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this
Agreement.
9.2. All insurance shall be from responsible companies duly authorized to do business in the
State of Florida.
9.3. All insurance policies required by this Agreement shall include the following provisions
and conditions by endorsement to the policies:
9.3.1. All insurance policies, other than the Business Automobile policy, Professional
Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet
the requirements of this Agreement shall name Collier County Board of County
Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier
County Government, as an additional insured as to the operations of CONSULTANT under
this Agreement and shall contain a severability of interests' provisions.
9.3.2. Companies issuing the insurance policy or policies shall have no recourse against
the COUNTY for payment of premiums or assessments for any deductibles which all are
at the sole responsibility and risk of CONSULTANT.
9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self-
insurance program carried by the COUNTY applicable to this Project, and the "Other
Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any
insurance or self-insurance program carried by the COUNTY applicable to this Project.
9.3.4. The Certificates of Insurance must read: For any and all work performed on
behalf of Collier County, or reference this contract number.
9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall
be construed in accordance with the laws of the State of Florida.
9.4. CONSULTANT, its subconsultants and the COUNTY shall waive all rights against each
other for damages covered by insurance to the extent insurance proceeds are paid and received
by the COUNTY, except such rights as they may have to the proceeds of such insurance held by
any of them.
9.5. All insurance companies from whom CONSULTANT obtains the insurance policies
required hereunder must meet the following minimum requirements:
9.5.1. The insurance company must be duly licensed and authorized by the Department
of Insurance of the State of Florida to transact the appropriate insurance business in the
State of Florida.
Page 9 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
ll
9.5.2. The insurance company must have a current A. M. Best financial rating of "Class
VI" or higher.
ARTICLE TEN
SERVICES BY CONSULTANT'S OWN STAFF
10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff,
unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use
of the services of any other person or firm by CONSULTANT, as independent consultant or
otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this
Agreement shall, however, be construed as constituting an agreement between the COUNTY and
any such other person or firm. Nor shall anything in this Agreement be deemed to give any such
party or any third party any claim or right of action against the COUNTY beyond such as may then
otherwise exist without regard to this Agreement.
10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign
to the Project to perform the Services required hereunder. Such personnel shall be committed to
this Project in accordance with the percentages noted in Schedule F. All personnel, identified in
Schedule F shall not be removed or replaced without the COUNTY's prior written consent.
10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors.
By appropriate written agreement, the CONSULTANT shall require each subconsultant or
subcontractor, to the extent of the Services to be performed by the subconsultant or
subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume
toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by
this Agreement, assumes toward the COUNTY. Each subconsultant or subcontract agreement
shall preserve and protect the rights of the COUNTY under this Agreement with respect to the
Services to be performed by the subconsultant or subcontractor so that the sub consulting or
subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall
require each subconsultant or subcontractor to enter into similar agreements with its sub-
subconsultants or sub-subcontractors.
10.4. CONSULTANT acknowledges and agrees that the COUNTY is a third-party beneficiary of
each contract entered into between CONSULTANT and each subconsultant or subcontractor,
however nothing in this Agreement shall be construed to create any contractual relationship
between the COUNTY and any subconsultant or subcontractor. Further, all such contracts shall
provide that, at the COUNTY's discretion, they are assignable to the COUNTY upon any
termination of this Agreement.
ARTICLE ELEVEN
WAIVER OF CLAIMS
11.1. CONSULTANT's acceptance of final payment shall constitute a full waiver of any and all
claims, except for insurance company subrogation claims, by it against the COUNTY arising out
of this Agreement or otherwise related to the Project, and except those previously made in writing
in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at
the time of the final payment. Neither the acceptance of CONSULTANT's services nor payment
by the COUNTY shall be deemed to be a waiver of any of the COUNTY's rights against
CONSULTANT.
Page 10 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
ARTICLE TWELVE
TERMINATION OR SUSPENSION
12.1. CONSULTANT shall be considered in material default of this Agreement and such default
will be considered cause for the COUNTY to terminate this Agreement, in whole or in part, as
further set forth in this section, for any of the following reasons: (a) CONSULTANT's failure to
begin services under the Agreement within the times specified under the Notice(s) to Proceed, or
b) CONSULTANT's failure to properly and timely perform the services to be provided hereunder
or as directed by the COUNTY, or (c) the bankruptcy or insolvency or a general assignment for
the benefit of creditors by CONSULTANT or by any of CONSULTANT's principals, officers or
directors, or (d) CONSULTANT's failure to obey any laws, ordinances, regulations or other codes
of conduct, or (e) CONSULTANT's failure to perform or abide by the terms and conditions of this
Agreement, or (f) for any other just cause. The COUNTY may so terminate this Agreement, in
whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the
material default.
12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it
is determined for any reason that CONSULTANT was not in default, or that its default was
excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT
provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1
shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and
CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those
afforded CONSULTANT under paragraph 12.3, below.
12.3. The COUNTY shall have the right to terminate this Agreement, in whole or in part, without
cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such
termination for convenience, CONSULTANT'S recovery against the COUNTY shall be limited to
that portion of the fee earned through the date of termination, together with any retainage withheld
and any costs reasonably incurred by CONSULTANT that are directly attributable to the
termination, but CONSULTANT shall not be entitled to any other or further recovery against the
COUNTY, including, but not limited to, anticipated fees or profits on work not required to be
performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably
possible.
12.4. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the
COUNTY all original papers, records, documents, drawings, models, and other material set forth
and described in this Agreement, including those described in Article 6, that are in
CONSULTANT's possession or under its control.
12.5. The COUNTY shall have the power to suspend all or any portions of the services to be
provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior
written notice of such suspension. If all or any portion of the services to be rendered hereunder
are so suspended, the CONSULTANT's sole and exclusive remedy shall be to seek an extension
of time to its schedule in accordance with the procedures set forth in Article Four herein.
12.6. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT
within forty-five (45) days after such payment is due or such other time as required by Florida's
Prompt Payment Act or (ii) the COUNTY otherwise persistently fails to fulfill some material
Page 11 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
p.0
obligation owed by the COUNTY to CONSULTANT under this Agreement, and (ii) the COUNTY
has failed to cure such default within fourteen (14) days of receiving written notice of same from
CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such
default is cured, after giving THE COUNTY a second fourteen (14) days written notice of
CONSULTANT's intention to stop performance under the Agreement. If the Services are so
stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of
the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other
persons performing portions of the Services under contract with the CONSULTANT, the
CONSULTANT may terminate this Agreement by giving written notice to the COUNTY of
CONSULTANT's intent to terminate this Agreement. If the COUNTY does not cure its default
within fourteen (14) days after receipt of CONSULTANT's written notice, CONSULTANT may,
upon fourteen (14) additional days' written notice to the COUNTY, terminate the Agreement and
recover from the COUNTY payment for Services performed through the termination date, but in
no event, shall CONSULTANT be entitled to payment for Services not performed or any other
damages from the COUNTY.
ARTICLE THIRTEEN
TRUTH IN NEGOTIATION REPRESENTATIONS
13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company
or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure
this Agreement and that CONSULTANT has not paid or agreed to pay any person, company,
corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT,
any fee, commission, percentage, gift or any other consideration contingent upon or resulting from
the award or making of this Agreement.
13.2. In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the
CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto
and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs
supporting the compensation for CONSULTANT's services to be provided under this Agreement
are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees
that the original Agreement price and any additions thereto shall be adjusted to exclude any
significant sums by which the COUNTY determines the Agreement price was increased due to
inaccurate, incomplete, or non-current wage rates and other factual unit costs. All such
adjustments shall be made within one (1) year following the end of this Agreement.
ARTICLE FOURTEEN
CONFLICT OF INTEREST
14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest,
either direct or indirect, which would conflict in any manner with the performance of services
required hereunder. CONSULTANT further represents that no persons having any such interest
shall be employed to perform those services.
ARTICLE FIFTEEN
MODIFICATION
15.1. No modification or change in this Agreement shall be valid or binding upon either party
unless in writing and executed by the party or parties intended to be bound by it.
Page 12 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
C
ARTICLE SIXTEEN
NOTICES AND ADDRESS OF RECORD
16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT
to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
the COUNTY's address of record:
Board of County Commissioners for Collier County, Florida
Division Name: Capital Project Planning, Impact Fees, and Program Mangement
Division Director: Amy Patterson
Address: 2685 Horseshoe Drive S
Naples, FL 34104
Administrative Agent/PM: Gary Putaansuu, Senior Project Manager
Telephone:239) 252-5876
E-Mail(s): Gary.Putaansuu@colliercountyfl.gov
16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to
the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United
States Postal Service Department, first class mail service, postage prepaid, addressed to the
following CONSULTANT's address of record:
Company Name: Aqnoli, Barber & Brundage, Inc.
Address: 7400 Trail Boulevard, Suite 200
Naples, FL 34108
Attention Name & Title: Dominick J. Amico
Telephone:239) 537-3111
E-Mail(s): amico@abbinc.com
16.3. Either party may change its address of record by written notice to the other party given in
accordance with requirements of this Article.
ARTICLE SEVENTEEN
MISCELLANEOUS
17.1. CONSULTANT, in representing the COUNTY, shall promote the best interests of the
COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair
dealing.
Page 13 of32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
17.2. No modification, waiver, suspension or termination of the Agreement or of any terms
thereof shall impair the rights or liabilities of either party.
17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by
CONSULTANT without the prior written consent of the COUNTY.
17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed
to be a waiver of any other breach and shall not be construed to be a modification of the terms of
this Agreement.
17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this
Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or
change the provisions in such Articles, Schedules, Parts and Attachments.
17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes
the entire agreement between the parties hereto and shall supersede, replace and nullify any and
all prior agreements or understandings, written or oral, relating to the matter set forth herein, and
any such prior agreements or understanding shall have no force or effect whatever on this
Agreement.
17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties
shall survive the expiration or termination of this Agreement.
17.8. This Agreement may be simultaneously executed in several counterparts, each of which
shall be an original and all of which shall constitute but one and the same instrument.
17.9. The terms and conditions of the following Schedules attached hereto are by this reference
incorporated herein:
Schedule A SCOPE OF SERVICES
Schedule B BASIS OF COMPENSATION
Schedule C PROJECT MILESTONE SCHEDULE
Schedule D INSURANCE COVERAGE
Schedule E CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE
Schedule F KEY PERSONNEL
Schedule G Other: Federal Grant Contract Provisions
Solicitation # 20-7678 including all Attachment(s), Exhibit(s) &Addendum
Consultant's Proposal
17.10. Grant Funded Projects (only applicable to Grant funded projects): In the event of any
conflict between or among the terms of any of the Contract Documents and/or the COUNTY's
Board approved Executive Summary, the terms of the Agreement shall take precedence over the
terms of all other Contract Documents, except the terms of any Supplemental Grant Conditions
shall take precedence over the Agreement. To the extent any conflict in the terms of the Contract
Documents cannot be resolved by application of the Supplemental Conditions, if any, or the
Agreement, the conflict shall be resolved by imposing the more strict or costly obligation under
the Contract Documents upon the CONSULTANT at the COUNTY's discretion.
Page 14 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
ARTICLE EIGHTEEN
APPLICABLE LAW
18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of
Florida, and by such laws, rules and regulations of the United States as made applicable to
services funded by the United States government. Any suit or action brought by either party to
this Agreement against the other party relating to or arising out of this Agreement must be brought
in the appropriate federal or state courts in Collier County, Florida, which courts have sole and
exclusive jurisdiction on all such matters.
ARTICLE NINETEEN
SECURING AGREEMENT/PUBLIC ENTITY CRIMES
19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company
or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure
this Agreement and that CONSULTANT has not paid or agreed to pay any person, company,
corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT,
any fee, commission, percentage, gift or any other consideration contingent upon or resulting from
the award or making of this Agreement. At the time this Agreement is executed, CONSULTANT
shall sign and deliver to the COUNTY the Truth-In-Negotiation Certificate identified in Article 13
and attached hereto and made a part hereof as Schedule E. CONSULTANT's compensation
shall be adjusted to exclude any sums by which the COUNTY determines the compensation was
increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs.
19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed
by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida
Statutes which read as follows:
A person or affiliate who has been placed on the convicted vendor list
following a conviction for a public entity crime may not submit a bid, proposal,
or reply on a contract to provide any goods or services to a public entity; may
not submit a bid, proposal, or reply on a contract with a public entity for the
construction or repair of a public building or public work; may not submit bids,
proposals, or replies on leases of real property to a public entity, may not be
awarded or perform work as a contractor, supplier, subcontractor, or
consultant under a contract with any public entity; and may not transact
business with any public entity in excess of the threshold amount provided in
s. 287.017 for CATEGORY TWO for a period of 36 months following the date
of being placed on the convicted vendor list."
ARTICLE TWENTY
DISPUTE RESOLUTION
20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any such
disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT
with full decision-making authority and by the COUNTY's staff person who would make the
presentation of any settlement reached during negotiations to the COUNTY for approval. Failing
resolution, and prior to the commencement of depositions in any litigation between the parties
Page 15 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
G
CI
arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation
before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation
shall be attended by representatives of CONSULTANT with full decision-making authority and by
the COUNTY's staff person who would make the presentation of any settlement reached at
mediation to the COUNTY's board for approval. Should either party fail to submit to mediation as
required hereunder, the other party may obtain a court order requiring mediation under section
44.102, Fla. Stat.
20.2. Any suit or action brought by either party to this Agreement against the other party relating
to or arising out of this Agreement must be brought in the appropriate federal or state courts in
Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters.
ARTICLE TWENTY-ONE
IMMIGRATION LAW COMPLIANCE
21.1. By executing and entering into this agreement, the CONSULTANT is formally
acknowledging without exception or stipulation that it is fully responsible for complying with the
provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq.
and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to
comply with the laws referenced herein shall constitute a breach of this agreement and the
COUNTY shall have the discretion to unilaterally terminate this Agreement immediately.
Page 16 of32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
IN WITNESS WHEREOF, the parties hereto have executed this Professional Services
Agreement the day and year first written above.
ATTEST: BOARD OF COUNTY COMMISSIONERS FOR
COLLIER COUNTY, FLORIDA
Crystal K. Kinzel, Clerk of Courts &
Comptroller
i' N:47-2p'. X.By. By:
t t
Date: CIIAIDCk"fl Burt L. Saunders Chairman
Attest as to Chairman's
Signature only.
sly
s to r and Legality:
County Attorney
Name
Consultant:
Consultant's Witnesses:
Agnoli, Barber& Brundage, Inc.
I1
By: i9-frr"4,41a,142—
fitness I,sp Dominick J. Amico, P.E., President
Name and Title Name and Title
Witness
AiS"a Ahdsr- i
12 Qirlc*r
Name and Title
Page 17 of 32
PSA CCNA Single Project Agreement 2017.010 Vcr.3
SCHEDULE A
SCOPE OF SERVICES
following this page (pages
1 through 7 )
Page 18 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
i&()
SCHEDULE A—SCOPE OF SERVICES
20-7678—Solana Road Stormwater Improvements Design Services
BACKGROUND
Solana Road Stormwater Improvements project is a part of the Gordon River Master Plan. The
purpose of the project is to reduce upstream flooding by improving the capacity of approximately
2,000 feet of culvert and 1,000 feet of open ditch. The project is located along the north side of
Solana Road starting from the west side of Goodlette-Frank Road and ending at the outfall into the
Gordon River east of Burning Tree Drive, in Collier County, Florida.
PURPOSE
The purpose of this scope of work is to describe the responsibilities of the CONSULTANT and
the COUNTY in connection with the design and preparation of a complete set of construction
contract plans and special provisions, if necessary, for:
Construction of a box culvert to replace existing pipes/culverts beginning on the west side of
Goodlette-Frank Road north of the intersection of Solana Road, crossing under Goodlette-Frank
Road, and continuing downstream along the north side of Solana Road to a point east of Burning
Tree Drive where it discharges into an open ditch. Then reconstruction of approximately 1,000
feet of open ditch from the box culvert end to an outfall at the upper Gordon River.Design Services
shall include a review of the Gordon River Master Plan recommendation for Solana Road to verify
the need for the increased capacity to relieve upstream flooding, the size of culvert needed, and,
should the recommendation be to replace the existing 4'x 8' box culvert, perform a cost benefit
analysis to evaluate options to allow it to remain in place.
The general objective is for the CONSULTANT to prepare a set of plans to be used by the
contractor to build the project, and by COUNTY to ensure the project is built as designed and to
specifications. Elements of work shall include roadways, drainage structures, geotechnical
activities, survey, drainage, signing and pavement markings, utility relocation, maintenance of
traffic, cost estimates, environmental permits, environmental mitigation plans, quantity
computation books, and all necessary incidental items for a complete project.
The Scope of Services establishes which items of work described in the FDOT Plan Preparation
Manual(s), and other pertinent manuals to accomplish the work, are specifically included in this
contract; and, which of the items of work will be the responsibility of the CONSULTANT or the
COUNTY.
All plans and design documents are to be prepared with standard English values in accordance
with all applicable Florida Department of Transportation (hereinafter referred to as FDOT)
Manuals and guidelines.
The CONSULTANT shall be aware that as a project is developed, certain modifications and/or
improvements to the original recommendation may be required. The CONSULTANT is to
incorporate these refinements into the design and will consider this effort to be an anticipated and
integral part of the work. This will not be a basis for any supplemental fee request(s).
Page 1 of 7
G:\1ALL SOLICITATIONS&TEMPLATES\1_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678_S chedul eA_S copeo fS ery i ces.do cx
The CONSULTANT shall demonstrate good project management practices while working on this
project. These include communication with the COUNTY and others as necessary, management
of time and resources, and documentation. The CONSULTANT shall set up and maintain
throughout the design of the project a contract file. It shall be the CONSULTANT's responsibility
to utilize the very best engineering judgment, practices and principles possible during the
prosecution of the work commissioned under this Agreement.
The COUNTY will provide contract administration, management services, and technical reviews
of all work associated with the development and preparation of the contract plans. The COUNTY
will provide job specific information and/or functions as outlined in this Agreement.
Task Description
i.Preliminary Discovery - The Consultant will review printed literature including
topographic maps, aerial photography (including historic photos) and ground water resources.
CONSULTANT shall identify areas with problematic soil and groundwater conditions, including:
Record drawings research
SFWMD pre-application meeting
City of Naples coordination including new record drawing information
Neighborhood outreach including Royal Poinciana Country Club
FDEM schedule update
Deliverables:
o Electronic copies of record drawings obtained
o SFWMD pre-application meeting notes
o City of Naples coordination including new record drawing information
o Electronic copies of any outreach materials/correspondence
o FDEM schedule
1 Surveying- The Consultant will perform a survey with site-specific data gathering in the
process of developing the design of this project, including:
Depict alignment and/or existing R/W lines (in required format) per COUNTY R/W
Maps, platted or dedicated rights of way.
Perform 3-dimensional (X,Y,Z) field location, or stakeout, of boring sites established
by geotechnical engineer. Includes field edits, analysis and processing of all field
collected data and/or reports.
Provide work zone as required by FDOT standards.
Perform all activities required to supervise and coordinate project.These activities must
be performed by the project supervisor, a Florida Professional Surveyor.
Horizontal and vertical control
Route boundary survey and inventory of inlets, manholes, etc.
Page 2 of 7
G:\1ALL SOLICITATIONS&TEMPLATES\1_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678__ScheduleA_S copeofServices.docx
9
Site topography survey
Channel and floodplain cross sections at outfall
Coordination of Subsurface Utility Exploration (SUE)
Documentation
Deliverables:
o Survey to be used as base mapping for construction plans. As such the survey is for
ABB Design use. A pdf file with topo points and existing topographic features will be
submitted. Please note this is not a boundary survey or official survey document.
1 Surveying (Subconsultant)
Subsurface Utility Exploration (SUE) Locate utilities using Ground Penetrating Radar
GPR)and Radio Detection. Paint and flag findings.Perform 12 soft digs(natural ground)
and 12 digs (asphalt/concrete) using vacuum excavation, locations to be determined by
ABB and County Project Manager.
Deliverables:
o SUE to be used as base mapping for construction plans. As such the SUE is for ABB
Design use. A pdf file with horizontal locations for GPIR and x, y, z locations for the
soft digs will be submitted.
2 Geotechnical (Subconsultant) - Provide geotechnical recommendations regarding the
proposed stormwater construction project including the following: description of the
site/alignment,design recommendations and discussion of any special considerations(i.e.removal
of unsuitable material, consolidation of weak soils, estimated settlement time/amount,
groundwater control,high groundwater conditions relative to pavement base,etc.). Also included:
Review available soil information
Standard penetration tests every 500'
GW level measurements
Visual and lab classifications
Subsurface assessment and engineering evaluation
Deliverables:
o Geotechnical Exploration Report.
3 Basis of Design Report(BDOR) (ABB)
Page 3 of 7
G:\1_ALL SOLICITATIONS&TEMPLATES\1_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678_ScheduleA_S copeofS ervi ces.docx
CA
Site characterization
Update H&H modeling and assess hydraulic performance of existing system
Cost benefit analysis (Options Analysis) (2 alternatives and the base project)
Develop recommended hydraulic design
Document BDOR
Deliverables:
o Cost benefit analysis of 2 alternative and the base project
o Draft BDOR
o Final BDOR
3 Basis of Design Report (BDOR) (Subconsultant)
Update H&H modeling and assess hydraulic performance of existing system
Cost benefit analysis (Options Analysis) (2 alternatives)
Develop recommended hydraulic design
Deliverables:
o To be submitted by Consultant
4 Final Design. The Consultant will deliver the plans depicting where the project impact
existing roadways, drainage features, existing utilities, existing signing, pavement markings, and
structures and the plans and specifications will describe how to restore them.
60%design formulation
Structural engineering coordination
Landscape design
Review and final design
Benefit cost analysis—per Grant Agreement
Constructability review
Engineer's estimate of probable cost
Develop plans and specifications
Deliverables:
o 60% design plans
o 60%Engineer's estimate of probable cost
o Final design plans
o Final Engineer's estimate of probable cost
o Benefit cost analysis
o Plan specifications
Page 4 of 7
G:\1ALL SOLICITATIONS&TEMPLATES\1_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678__S eheduleA_ScopeofServices.docx
4 Final Design (Subconsultant)
Structural engineering
Engineer's estimate of probable cost
Deliverables:
o Design plans and EOPC to be included with Consultant's submittals
5 Public Involvement - Public involvement is an important aspect of the project
development process. Public involvement includes communicating to all interested persons,
groups, and government organizations information regarding the development of the project.
Property owners adjacent to project, including those that use the golf courses, shall be informed
about the project.
Public Meetings may be held on this project at the 60% design stage. In addition, the Consultant
and County staff will meet with civic groups and others on an individual basis, as needed, to
discuss the project.
Project open house (1)
Deliverables:
o Design displays presented at meeting
5 Public Involvement (Subconsultant)
Project open house (1)
Deliverables:
o Press release
o Project handouts
o Sign-in sheet
o Comment cards
o Meeting summary
6 Permitting-The Consultant will apply for and secure all necessary permits needed to build
the project, including:
ERP and dewatering application for SFWMD
SFWMD pre-app (recommended to be done at project start)
Page 5 of 7
G:\1_ALL SOLICITATIONS&TEMPLATES\1_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678_S cheduleA_S copeofServices.docx
CA()
Right of Way permit
Respond to RAIs
Final Permit procurement
Deliverables:
o Electronic copies of all permit submittals
o Electronic copies of all RAIs
o Electronic copies of all permits
6 Permitting (Subconsultant)
Environmental assessment of project and T&E species evaluation
Deliverables:
o Environmental Assessment
o T&E Species Evaluation
7 Post-Design Service (ABB)
Utility coordination
Bid documents
Bidding assistance
Letter of Recommended Award
Contractor Reference Check
Engineer of Record services during construction
Shop drawing review and approval
Record drawings and final construction certification (5)
Deliverables:
o Letter of Recommended Award
o Contractor references
o Electronic copies of all shop drawing reviews
o Record drawings
o Construction/permit certifications
7 Post-Design Service(Subconsultant
Shop drawing review and approval
Deliverables:
Page 6 of 7
G:\I ALL SOLICITATIONS&TEMPLATES\I_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678_ScheduleA_ScopeofServices.docx
o Electronic copies of all shop drawing reviews
8 Reimbursables
As allowed under the contract
Note: Monthly progress billings are not tied to deliverables. Some tasks will take multiple billing
periods to complete to the deliverable stage. Progress billings will be allowed prior to deliverable
provision.
Page 7 of 7
G:11ALL SOLICITATIONS&TEMPLATES\I_FY 2020\20-7678 Solana Road Stormwater Improvements Design\20-
7678__ScheduleA_S eopeofS ervices.docx
CAO
SCHEDULE B
BASIS OF COMPENSATION
1. MONTHLY STATUS REPORTS
B.1.1. As a condition precedent to payment, CONSULTANT shall submit to the COUNTY as part
of its monthly invoice a progress report reflecting the Project status, in terms of the total work
effort estimated to be required for the completion of the Basic Services and any authorized
Additional Services, as of the last day of the subject monthly billing cycle. Among other things,
the report shall show all Service items and the percentage complete of each item.
2. COMPENSATION TO CONSULTANT
B.2.1. For the Basic Services provided for in this Agreement, the COUNTY agrees to make the
payments to CONSULTANT in accordance with the terms stated below. Payments will be made
in accordance with the following Schedule; however, the payment of any particular line item noted
below shall not be due until services associated with any such line item have been completed or
partially completed to the COUNTY's reasonable satisfaction. Lump sum payments will be made
upon the percentage complete. In no event shall such Time and Materials compensation exceed
the amounts set forth in the table below.
Tasks/Item Description Lump Sum Time and
Materials
Not-To-
Exceed
Preliminary Discovery 15,870.00
1 Surveying(ABB) 41,901.00
1 Surveying(Subconsultant) 10,840.00
2 Geotechnical(Subconsultant) 6,742.00
3 Basis of Design Report(BDOR)(ABB) 29,822.00
3 Basis of Design Report(BDOR)(Subconsultant,) 53,058.00
4 Final Design(ABB) 87,756.00
4 Final Design(Subconsultant 66,246.00
5 Public Involvement(ABB) 5,083.00
5 Public Involvement(Subconsultant) 18,500.00
6 Permitting(ABB) 33,965.00
6 Permitting(Subconsultant) 29,185.00
7 Post-Design Services(ABB) 88,620.00
7 Post-Design Services(Subconsultant) 4,900.00
Reimbursables 3,800.00
5%Subconsultant Mark-Up 9,473.55
Total Lump Sum Fee 202,744.55
Total Time and Materials Fee 303,017.00
GRAND TOTAL FEE 505,761.55 $
Page 19 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
CM)
B.2.2. Ei*Time and Material Fees: The fees noted in Section B.2.1. shall constitute the amounts
to be paid to CONSULTANT for the performance of the Basic Services. Direct Labor Costs mean
the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT's personnel,
with respect to this Project, including all indirect payroll related costs and fringe benefits, all in
accordance with and not in excess of the rates set forth in the Attachment 1 to this Schedule B.
With each monthly Application for Payment, CONSULTANT shall submit detailed time records,
and any other documentation reasonably required by the COUNTY, regarding CONSULTANT's
Direct Labor Costs incurred at the time of billing, to be reviewed and approved by the COUNTY.
There shall be no overtime pay without the COUNTY's prior written approval.
B.2.2.1. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's
monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable
not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has
completed such task as of that particular monthly billing.
B.2.3. Er Lump Sum Fees: The fees noted in Section 2.1. shall constitute the lump sum amount
to be paid to CONSULTANT for the performance of the Basic Services. There shall be no
overtime pay without the COUNTY's prior written approval.
B.2.3.1 CONSULTANT shall submit, with each of the monthly status reports provided for
under Section B.1.1 of this Schedule B, an invoice for fees earned in the performance of Basic
Services and Additional Services during the subject billing month.
B.2.4. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the
COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based
on the services to be provided and as set forth in the Amendment authorizing such Additional
Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this
Schedule B and all Reimbursable Expenses shall comply with the provision of Section 3.4.1
below. There shall be no overtime pay on Additional Services without the COUNTY's prior written
approval.
B.2.5. The compensation provided for under Section B.2.1 of this Schedule B, shall be the total
and complete amount payable to CONSULTANT for the Basic Services to be performed under
the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies
and out-of-pocket expenses incurred in the performance of all such services.
B.2.6. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges
and agrees that in the event of a dispute concerning payments for Services performed under this
Agreement, CONSULTANT shall continue to perform the Services required of it under this
Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the
COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are
due and payable.
3. SCHEDULE OF PAYMENTS
B.3.1. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more
than one invoice per month for all fees earned that month for both Basic Services and Additional
Services. Invoices shall be reasonably substantiated, identify the services rendered and must be
submitted in triplicate in a form and manner required by the COUNTY.
Page 20 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
1 C)
B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon
receipt and approval of invoices submitted on the date of services or within six (6) months after
completion of contract. Any untimely submission of invoices beyond the specified deadline period
is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall
be deemed of the essence with respect to the timely submission of invoices under this Agreement.
B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done,
no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted
on CONSULTANT's letterhead and must include the Purchase Order Number and Project name
and shall not be submitted more than one time monthly.
B.3.3. Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove
and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with
supporting documentation.
B.3.4. Unless specific rates have been established in Attachment 1, attached to this Schedule B,
CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by
CONSULTANT for this Agreement or Additional Services, CONSULTANT shall be limited to a
maximum markup of five percent (5%) on the fees and expenses associated with such
subconsultants and subcontractors.
B.3.4.1 Reimbursable Expenses must comply with §112.061, Fla. Stat., or as set forth in
the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the
following items:
B.3.4.1.1. Cost for reproducing documents that exceed the number of documents
described in this Agreement and postage and handling of Drawings and Specifications.
B.3.4.1.2. Travel expenses reasonably and necessarily incurred with respect to
Project related trips, to the extent such trips are approved by the COUNTY. Such expenses, if
approved by the COUNTY, may include coach airfare, standard accommodations and meals, all
in accordance with §112.061, Fla. Stat. Further, such expenses, if approved by the COUNTY,
may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such
trips within Collier and Lee Counties are expressly excluded.
B.3.4.1.3. Permit Fees required by the Project.
B.3.4.1.4. Expense of overtime work requiring higher than regular rates approved in
advance and in writing by the COUNTY.
B.3.4.1.5. Expense of models for the County's use.
B.3.4.1.6. Other items on request and approved in writing by the COUNTY.
B.3.4.1.7. The CONSULTANT shall bear and pay all overhead and other expenses,
except for authorized reimbursable expenses, incurred by CONSULTANT in the performance of
the Services.
Page 21 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
B.3.4.1.8. Records of Reimbursable Expenses shall be kept on a generally
recognized accounting basis.
B.3.5. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring
any reimbursable expenses, and absent such prior approval, no expenses incurred by
CONSULTANT will be deemed to be a reimbursable expense.
Page 22 of 32
PSA CCNA Single Project Agreement 2017.010 Ver.3
S
SCHEDULE B —ATTACHMENT 1
CONSULTANT'S HOURLY RATE SCHEDULE
Title Hourly Rate
Principal 238
Project Manager 165
Engineer 136
Principal/Senior Landscape Architect 165
Senior Designer 128
Senior Technician 102
CADD Technician 95
Surveyor and Mapper 142
Survey Crew-2 man 152
The above hourly rates are applicable to Time and Materials task(s) only. The above list may not
be all inclusive. Additional hourly rates for other personnel may be added via an Amendment
upon mutual agreement in advance and in writing by the parties. For Grant Funded Projects,
the above hourly rates are for purposes of providing estimate(s), as required by the grantor
agency.
Page 23 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
SCHEDULE C
PROJECT MILESTONE SCHEDULE
Number of Calendar
Task/Item Days For Completion
Description of Task from Date of
Notice to Proceed f
Preliminary Discovery (Alternatives) 60
1 Surveying 90
2 Geotechnical 120
3 Basis of Design Report (BODR) 150
4 Final Design 270
5 Public Involvement Continuous throughout the
project
6 Permitting 300
7 Post-Design Services TBD
TOTAL CALENDAR DAYS FOR PROJECT 2487
COMPLETION FROM NTP
Page 24 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
S
SCHEDULE D
INSURANCE COVERAGE
1. The amounts and types of insurance coverage shall conform to the following minimum
requirements with the use of Insurance Services Office (ISO) forms and endorsements or their
equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the
below listed minimum required coverages, CONSULTANT must identify on the Certificate of
Insurance the nature and amount of such self-insured retentions or deductibles and provide
satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or
deductibles will be CONSULTANT's sole responsibility.
2. The insurance required by this Agreement shall be written for not less than the limits
specified herein or required by law, whichever is greater.
3.Coverages shall be maintained without interruption from the date of commencement of the
services until the date of completion and acceptance of the Project by the COUNTY or as specified
in this Agreement, whichever is longer.
4. Certificates of insurance acceptable to the COUNTY shall be filed with the COUNTY within
ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact
that CONSULTANT has acquired and put in place the insurance coverages and limits required
hereunder. In addition, certified, true and exact copies of all insurance policies required shall be
provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall
contain a provision that coverages afforded under the policies will not be canceled or allowed to
expire until at least thirty (30) days prior written notice has been given to the COUNTY.
CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after
receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or
limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve
CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate
limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately
take steps to have the aggregate limit reinstated to the full extent permitted under such policy.
5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self-
insurance program carried by the COUNTY applicable to this Project.
6. The acceptance by the COUNTY of any Certificate of Insurance does not constitute
approval or agreement by the COUNTY that the insurance requirements have been satisfied or
that the insurance policy shown on the Certificate of Insurance is in compliance with the
requirements of this Agreement.
7. CONSULTANT shall require each of its subconsultants to procure and maintain, until the
completion of the subconsultant's services, insurance of the types and to the limits specified in
this Section except to the extent such insurance requirements for the subconsultant are expressly
waived in writing by the COUNTY.
Page 25 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
8. Should at any time the CONSULTANT not maintain the insurance coverages required
herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to
purchase such coverages and charge the CONSULTANT for such coverages purchased. If
CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand,
the COUNTY has the right to offset these costs from any amount due CONSULTANT under this
Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY
shall be under no obligation to purchase such insurance, nor shall it be responsible for the
coverages purchased or the insurance company or companies used. The decision of the
COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of
any of its rights under the Agreement.
9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the
completion of the services required hereunder or termination of the Agreement, the
CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of
Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the
Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material
breach by CONSULTANT and the COUNTY may terminate the Agreement for cause.
10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY.
Required by this Agreement? Ill Yes I I No
Workers' Compensation and Employers' Liability Insurance shall be maintained by the
CONSULTANT during the term of this Agreement for all employees engaged in the work under
this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance
shall not be less than:
a. Worker's Compensation - Florida Statutory Requirements
b. Employers' Liability - The coverage must include Employers' Liability with a
minimum limit of$ 1,000,000 for each accident.
The insurance company shall waive all claims rights against the COUNTY and the policy shall be
so endorsed.
11. United States Longshoreman's and Harbor Worker's Act coverage shall be maintained
where applicable to the completion of the work. Required by this Agreement? Yes U No
12. Maritime Coverage (Jones Act) shall be maintained where applicable to the completion
of the work.
Required by this Agreement? I I Yes U No
13. COMMERCIAL GENERAL LIABILITY.
Required by this Agreement? II Yes I No
A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be
maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury,
Page 26 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent
Contractors, Broad Form Property Damage including Completed Operations and Products and
Completed Operations Coverage. Products and Completed Operations coverage shall be
maintained for a period of not less than five (5) years following the completion and acceptance by
the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the
following:
Coverage shall have minimum limits of $ 1,000,000 Per Occurrence,
2,000,000 aggregate.
B. The General Aggregate Limit shall apply separately to this Project and the policy shall
be endorsed using the following endorsement wording. "This endorsement modifies insurance
provided under the following: Commercial General Liability Coverage Part. The General
Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away
from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall
be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the
CONSULTANT shall be subject to the approval of the Risk Management Director or his/her
designee.
14. Collier County Board of County Commissioners, OR, Board of County Commissioners in
Collier County, OR, Collier County Government shall be listed as the Certificate Holder and
included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability
where required. The insurance shall be primary and non-contributory with respect to any other
insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's
policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with
the same insurance requirements that the Contractor is required to meet.
15. Watercraft Liability coverage shall be carried by the CONSULTANT or the
SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in
subparagraph (1) above if applicable to the completion of the Services under this Agreement.
Required by this Agreement? Yes III No
16. Aircraft Liability coverage shall be carried by the CONSULTANT or the
SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the
completion of the Services under this Agreement.
Required by this Agreement? n Yes n No
17. AUTOMOBILE LIABILITY INSURANCE.
Required by this Agreement? n Yes n No
Business Auto Liability: Coverage shall have minimum limits of $500,000 Per
Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This
shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-The
ownership.
Page 27 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
CA(1
18. TECHNOLOGY ERRORS AND OMISSIONS INSURANCE.
Required by this Agreement? Yes I.I No
Technology Errors and Omissions Insurance: Coverage shall have minimum limits of
Per Occurrence.
19. CYBER INSURANCE.
Required by this Agreement? Yes No
Cyber Insurance: Coverage shall have minimum limits of$ Per Occurrence.
20. UMBRELLA LIABILITY.
A. Umbrella Liability may be maintained as part of the liability insurance of the
CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial
General Liability, and Automobile Liability coverages required herein and shall include all
coverages on a "following form" basis.
B. The policy shall contain wording to the effect that, in the event of the exhaustion of any
underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as
primary insurance.
21. PROFESSIONAL LIABILITY INSURANCE.
Required by this Agreement? n Yes I I No
A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its
legal liability for claims arising out of the performance of professional services under this
Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under
this insurance. Such insurance shall have limits of not less than $ 1,000,000 each claim and
aggregate.
B. Any deductible applicable to any claim shall be the sole responsibility of the
CONSULTANT. Deductible amounts are subject to the approval of the COUNTY.
C. The CONSULTANT shall continue this coverage for this Project for a period of not
less than five (5) years following completion and acceptance of the Project by the COUNTY.
D. The policy retroactive date will always be prior to the date services were first
performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the
term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit
Certificates of Insurance providing for an unqualified written notice to the COUNTY of any
cancellation of coverage or reduction in limits, other than the application of the aggregate limits
provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within
twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or
material change in coverages or limits received by CONSULTANT from its insurer. In the event
Page 28 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
CA()
of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT
shall immediately take steps to have the aggregate limit reinstated to the full extent permitted
under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and
any endorsements issued or to be issued on the policy if requested by the COUNTY.
22. VALUABLE PAPERS INSURANCE.
In the sole discretion of the COUNTY, CONSULTANT may be required to purchase
valuable papers and records coverage for plans, specifications, drawings, reports, maps, books,
blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or
reconstructing valuable papers or records utilized during the term of this Agreement.
23. PROJECT PROFESSIONAL LIABILITY.
A. If the COUNTY notifies CONSULTANT that a project professional liability policy will
be purchased, then CONSULTANT agrees to use its best efforts in cooperation with the COUNTY
and the COUNTY's insurance representative, to pursue the maximum credit available from the
professional liability carrier for a reduction in the premium of CONSULTANT's professional liability
policy. If no credit is available from CONSULTANT's current professional policy underwriter, then
CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a
renewal occurs during the term of the project policy (and on any subsequent professional liability
policies that renew during the term of the project policy). CONSULTANT agrees that any such
credit will fully accrue to the COUNTY. Should no credit accrue to the COUNTY, the COUNTY
and CONSULTANT, agree to negotiate in good faith a credit on behalf of the COUNTY for the
provision of project-specific professional liability insurance policy in consideration for a reduction
in CONSULTANT's self-insured retention and the risk of uninsured or underinsured consultants.
B. The CONSULTANT agrees to provide the following information when requested by
the COUNTY or the COUNTY's Project Manager:
1. The date the professional liability insurance renews.
2. Current policy limits.
3. Current deductibles/self-insured retention.
4. Current underwriter.
5. Amount (in both dollars and percent) the underwriter will give as a credit if the
policy is replaced by an individual project policy.
6. Cost of professional insurance as a percent of revenue.
7. Affirmation that the design firm will complete a timely project errors and omissions
application.
C. If the COUNTY elects to purchase a project professional liability policy,
CONSULTANT to be insured will be notified and the COUNTY will provide professional liability
insurance, naming CONSULTANT and its professional subconsultants as named insureds.
END OF SCHEDULE D
Page 29 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
CAZ)
SCHEDULE E
TRUTH IN NEGOTIATION CERTIFICATE
In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida
Statutes, Agnoli, Barber & Brundage, Inc. company's name)
hereby certifies that wages, rates and other factual unit costs supporting the compensation for the
services of the CONSULTANT to be provided under the Professional Services Agreement,
concerning " Solana Road Stormwater Improvements Design Services project
is accurate, complete and current as of the time of contracting.
BY:
ominick J. A ico, P.E.
TITLE: President
DATE: /06/Z6Z°
Page 30 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver,3
CA
SCHEDULE F
KEY PERSONNEL
Name Personnel Category Percentage
of Time
Dominick J. Amico, PE Principal 5%
James A. Carr, PE Principal 5%
Edward F. Tryka, Ill, PE Project Manager 17%
Engineer 23%
Brent C. Guillot, RLA Principal/Senior Landscape Architect 2%
Senior Designer 11%
Senior Tech 26%
CADD Tech 2%
Wayne Agnoli, PSM Surveyor & Mapper 3%
George Hackney, PSM Surveyor & Mapper 3%
Survey Crew 2-man 6%
Page 31 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
CAO
SCHEDULE G
Other:
Federal Grant Contract Provisions
Description)
ICI following this page (pages
1
through
10 )
n this schedule is not applicable
Page 32 of 32
PSA_CCNA Single Project Agreement 2017.010 Ver.3
EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS
COLLIER COUNTY
FEMA-HAZARD MITIGATION GRANT PROGRAM(HMGP)
CONTRACT PROVISIONS
CFDA 97.039
This project activity is funded in whole or in part by the Federal Government, or an Agency thereof. Federal Law
requires that the Applicant's contracts relating to the project include certain provisions.
The supplemental conditions contained in this section are intended to cooperate with, to supplement, and to modify
the general conditions and other specifications. In cases of disagreement with any other section of this contract, the
Supplemental Conditions shall govern.
Per uniform requirements of federal awards (2 CFR Part 200.23) the definition of CONTRACTOR is an entity that
receives a contract(including a purchase order).
Compliance with Federal Law, Regulations and Executive Orders:The Sub-Recipient(County)agrees to include
in the subcontract that (I) the subcontractor is bound by the terms of the Federally-Funded Subaward and Grant
Agreement, (ii) the subcontractor is bound by all applicable state and Federal laws and regulations, and (iii) the
subcontractor shall hold the Division and Sub-Recipient harmless against all claims of whatever nature arising out of
the subcontractor's performance of work under this Agreement,to the extent allowed and required by law.
Specifically, the Contractor shall be responsible for being knowledgeable and performing any and all services under
this contract in accordance with the following governing regulations along with any and all other relevant Federal,State,
and local laws, regulations,codes and ordinances:
The Hazard Mitigation Grant Program(HMGP)is generally governed by the following statutes and regulations:
O 2 C.F.R.Part 200 Uniform Administrative Requirements,Cost Principles,and Audit Requirements
for Federal Awards
O 44 C.F.R. Parts 7,9,10,13,14,17,18,25,206,220,and 221,and any other applicable FEMA policy
memoranda and guidance document;
o The Robert T.Stafford Disaster Relief and Emergency Assistance Act
o State of Florida Administrative Plan for the Hazard Mitigation Grant Program
FCP-1
0
EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS
APPLICABLE FEMA HMGP PROVISIONS
Access to Records:(1)The contractor agrees to provide the County,the FEMA Administrator,the Comptroller General of
the United States, or any of their authorized representative's access to any books, documents, papers, and records of
the Contractor which are directly pertinent to this contract for the purposes of making audits,examinations,excerpts,and
transcriptions. (2)The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever
or to copy excerpts and transcriptions as reasonably needed. (3) The contractor agrees to provide the FEMA
Administrator or his authorized representatives'access to construction or other work sites pertaining to the work being
completed under the contract. (4) In compliance with the Disaster Recovery Act of 2018, Collier County and the
Contractor acknowledge and agree that no language in this contract is intended to prohibit audits or internal reviews by
the FEMA Administrator or the Comptroller General of the United States.
Administrative,Contractual,or Legal Remedies:
Applies to contracts greater than the simplified acquisition threshold, currently set at$250,000.
Unless otherwise provided in this contract, all claims, counter-claims, disputes and other matters in question between
the local government and the contractor, arising out of or relating to this contract,or the breach of it,will be decided by
arbitration, if the parties mutually agree,or in a Florida court of competent jurisdiction.
Americans with Disabilities Act: The contractor agrees to comply with the Americans with Disabilities Act (Public
Law 101-336, 42 U.S.C. Section 12101 et seq.), which prohibits discrimination by public and private entities on the
basis of disability in employment, public accommodations, transportation, State and local government services, and
telecommunications.
Buy America Act:
Applies to subcontracts.
The contractor agrees to comply with 41 U.S.C. 10a. All unmanufactured and manufactured articles, materials and
supplies which are acquired for public use must have been produced in the United States as required under 41 U.S.C.
10a,unless it would not be in the public interest or unreasonable in cost.
Byrd Anti-Lobbying Amendment:
Applies to contracts>$100,000.
Contractors who apply or bid for an award of$100,000 or more shall file the required certification. Each tier certifies to
the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for
influencing or attempting to influence an officer or employee of any agency,a member of Congress,officer or employee
of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract,grant,or any
other award covered by 31 U.S.C. § 1352. Each tier shall also disclose any lobbying with non-Federal funds that takes
place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the
recipient.
Changes:See Standard Purchase Order Terms and Conditions.
Clean Air Act and the Federal Water Pollution Control Act:
Applies to all contracts and subcontracts>$150,000.
Contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act
42 U.S.C.7401-7671q)and the Federal Water Pollution Control Act as amended(33 U.S.C. 1251-1387)and will report
violations to FEMA and the Regional Office of the Environmental Protection Agency(EPA).
Compliance with Federal Law,Regulations,and Executive Orders:
This is an acknowledgement that FEMA financial assistance will be used to fund the contract only. The contractor will
comply will all applicable federal law,regulations,executive orders, FEMA policies,procedures,and directives.
Contract Work Hours and Safety Standards:
Applies to Contracts>$100,000 and involves the employment of mechanics or laborers.
29 C.F.R.§5.5(b)
1) Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may
require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any
workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such
laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all
hours worked in excess of forty hours in such workweek.
FCP-2
EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS
2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in
paragraph (1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid
wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done
under contract for the District of Columbia or a territory,to such District or to such territory),for liquidated damages.
Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen
and guards, employed in violation of the clause set forth in paragraph ( 1)of this section, in the sum of$10 for each
calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty
hours without payment of the overtime wages required by the clause set forth in paragraph(1)of this section.
3)Withholding for unpaid wages and liquidated damages.The(write in the name of the Federal agency or the loan or
grant recipient)shall upon its own action or upon written request of an authorized representative of the Department of
Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or
subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other
federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same
prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or
subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2) of this
section.
4)Subcontracts.The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph(1)
through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier
subcontracts.The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor
with the clauses set forth in paragraphs(1)through(4)of this section."
Contracting with Small and Minority Businesses, Women's Business Enterprises, and Labor Surplus Area
Firms:
200.321 (a) The Solicitor must take all necessary affirmative steps to assure that minority businesses, women's
business enterprises,and labor surplus area firms are used whenever possible.(b)Affirmative steps must include:
1) Placing qualified small and minority businesses and women's business enterprises on solicitation
lists;
2) Assuring that small and minority businesses, and women's business enterprises are solicited
whenever they are potential sources;
3) Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit
maximum participation by small and minority businesses,and women's business enterprises;
4) Establishing delivery schedules, where the requirement permits, which encourage participation by
small and minority businesses,and women's business enterprises;
5) Using the services and assistance, as appropriate, of such organizations as the Small Business
Administration and the Minority Business Development Agency of the Department of Commerce;and
6) Requiring the prime contractor, if subcontracts are to be let, to take the affirmative steps listed in
paragraphs(1)through(5)of this section.
b.The requirement outlined in subparagraph a. above,sometimes referred to as"socioeconomic contracting,"does not
impose an obligation to set aside either the solicitation or award of a contract to these types of firms. Rather, the
requirement only imposes an obligation to carry out and document the six affirmative steps identified above.
c. The "socioeconomic contracting" requirement outlines the affirmative steps that the Sub-Recipient must take; the
requirements do not preclude the Sub-Recipient from undertaking additional steps to involve small and minority
businesses and women's business enterprises.
d. The requirement to divide total requirements, when economically feasible, into smaller tasks or quantities to permit
maximum participation by small and minority businesses,and women's business enterprises, does not authorize the
Sub-Recipient to break a single project down into smaller components in order to circumvent the micro-purchase or
small purchase thresholds so as to utilize streamlined acquisition procedures(e.g."project splitting").
FCP-3
0
EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS
Copeland"Anti-Kickback"Act:
a. Contractor.The contractor shall comply with 18 U.S.C.§874,40 U.S.C.§ 3145, and the requirements of 29 C.F.R.
pt. 3 as may be applicable,which are incorporated by reference into this contract.
b. Subcontracts. The contractor or subcontractor shall insert in any subcontracts the clause above and such other
clauses as FEMA may by appropriate instructions require, and also a clause requiring the subcontractors to include
these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any
subcontractor or lower tier subcontractor with all of these contract clauses.
c.Breach.A breach of the contract clauses above may be grounds for termination of the contract,and for debarment
as provided in 29 C.F.R.§5.12.
Debarment and Suspension: (1)This contract is a covered transaction for purposes of 2 C.F.R. pt. 180 and 2 C.F.R.
pt. 3000. As such the contractor is required to verify that none of the contractor, its principals (defined at 2 C.F.R. §
180.995), or its affiliates (defined at 2 C.F.R. § 180.905)are excluded (defined at 2 C.F.R. § 180.940) or disqualified
defined at 2 C.F.R. § 180.935). (2)The contractor must comply with 2 C.F.R. pt. 180,subpart C and 2 C.F.R.pt.3000,
subpart C and must include a requirement to comply with these regulations in any lower tier covered transaction it
enters into, (3)This certification is a material representation of fact relied upon by the County. If it is later determined
that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, in addition to
remedies available to the County, the Federal Government may pursue available remedies, including but not limited to
suspension and/or debarment. (4)The bidder or proposer agrees to comply with the requirements of 2 C.F.R. pt. 180,
subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may
arise from this offer.The bidder or proposer further agrees to include a provision requiring such compliance in its lower
tier covered transactions.
DHS Seal, Logo, and Flags: The contractor shall not use the DHS seal(s), logos, crests, or reproductions of flags or
likenesses of DHS agency officials without specific FEMA pre- approval. This is an acknowledgement that FEMA
financial assistance will be used to fund all or a portion of the contract. The contractor will comply with all applicable
Federal law, regulations,executive orders, FEMA policies,procedures,and directives.
Energy Efficiency Standards: The contractor agrees to comply with mandatory standards and policies relating to
energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy
and Conservation Act(42 U.S.C.6201).
Equal Employment Opportunity Clause (§60-1.4): Except as otherwise provided under 41 C.F.R. Part 60, at
contracts that meet the definition of"federally assisted construction contract" in 41 C.F.R. § 60-1.3 must include the
equal opportunity clause provided under 41 C.F.R.§60-1.4(b).
During the performance of this contract,the contractor agrees as follows:
I. The contractor will not discriminate against any employee or applicant for employment because of race,color,
religion, sex, sexual orientation, gender identity, or national origin.The contractor will take affirmative action to
ensure that applicants are employed, and that employees are treated during employment, without regard to
their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall include,
but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment, or recruitment
advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training,
including apprenticeship. The contractor agrees to post in conspicuous places, available to employees and
applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this
nondiscrimination clause.
II. The contractor will, in all solicitations or advertisements for employees placed by or on behalf of the contractor,
state that all qualified applicants will receive consideration for employment without regard to race, color,
religion,sex, sexual orientation,gender identity,or national origin.
III. The contractor will not discharge or in any other manner discriminate against any employee or applicant for
employment because such employee or applicant has inquired about, discussed, or disclosed the
compensation of the employee or applicant or another employee or applicant.This provision shall not apply to
instances in which an employee who has access to the compensation information of other employees or
applicants as a part of such employee's essential job functions discloses the compensation of such other
employees or applicants to individuals who do not otherwise have access to such information, unless such
disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding,
FCP-4
EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS
hearing, or action, including an investigation conducted by the employer, or is consistent with the contractor's
legal duty to furnish information.
IV. The contractor will send to each labor union or representative of workers with which it has a collective
bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting
officer,advising the labor union or workers'representative of the contractor's commitments under section 202 of
Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places
available to employees and applicants for employment.
V. The contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the
rules,regulations,and relevant orders of the Secretary of Labor.
VI. The contractor will furnish all information and reports required by Executive Order 11246 of September 24,
1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit
access to his books,records,and accounts by the contracting agency and the Secretary of Labor for purposes of
investigation to ascertain compliance with such rules,regulations,and orders.
VII. In the event of the contractor's non-compliance with the nondiscrimination clauses of this contract or with any of
such rules, regulations, or orders, this contract may be canceled, terminated or suspended in whole or in part
and the contractor may be declared ineligible for further Government contracts in accordance with procedures
authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and
remedies invoked as provided in Executive Order 11246 of September 24, 1965,or by rule, regulation,or order
of the Secretary of Labor,or as otherwise provided by law.
VIII. The contractor will include the provisions of paragraphs(1)through(8)in every subcontract or purchase order
unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of
Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each
subcontractor or vendor.The contractor will take such action with respect to any subcontract or purchase order
as may be directed by the Secretary of Labor as a means of enforcing such provisions including sanctions for
noncompliance: Provided, however,that in the event the contractor becomes involved in,or is threatened with,
litigation with a subcontractor or vendor as a result of such direction, the contractor may request the United
States to enter into such litigation to protect the interests of the United States.
No Obligation by Federal Government: The Federal Government is not a party to this contract and is not subject to
any obligations or liabilities to the non-Federal entity, contractor, or any other party pertaining to any matter resulting
from the contract.
Procurement of Recovered Materials(§200.322):
Requirements:
The requirements of Section 6002 include procuring only items designated in guidelines of the EPA at 40 C.F.R. Part
247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory
level of competition,where the purchase price of the Item exceeds$10,000 or the value of the quantity acquired by the
preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes
energy and resource recovery; and establishing an affirmative procurement program for procurement of recovered
materials identified in the EPA guidelines.
1) In the performance of this contract, the Contractor shall make maximum use of products containing recovered
materials that are EPA designated items unless the product cannot be acquired (i) Competitively within a timeframe
providing for compliance with the contract performance schedule; (ii)Meeting contract performance requirements;or(iii)
At a reasonable price. (2) Information about this requirement is available at EPA's Comprehensive Procurement
Guidelines web site,gr ar (3)The Contractor
also agrees to comply with all other applicable requirements of Section 6002 of the Solid Waste Disposal Act.
Program Fraud and False or Fraudulent Statements or Related Acts: The contractor acknowledges that 31 U.S.C.
Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the contractor's actions pertaining to
this contract.
Reporting: The contractor will provide any information required to comply with the grantor agency requirements and
regulations pertaining to reporting. It is important that the contractor is aware of the reporting requirements of the
County, as the Federal or State granting agency may require the contractor to provide certain information,
documentation,and other reporting in order to satisfy reporting requirements to the granting agency.
FCP-5
EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS
Termination for Cause and Convenience:
Applies to all contracts>$10,000.
Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this
Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for
convenience with a thirty(30) day written notice.The County shall be sole judge of non-performance. In the event that
the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the
Agreement Amount earned through the date of termination. The Contractor shall not be entitled to any other or further
recovery against the County, including, but not limited to, any damages or any anticipated profit on portions of the
services not performed.
STATE PROVISIONS
Convicted Vendor and Discriminatory Vendors List: Those who have been placed on the convicted vendor list
following a conviction for a public entity crime or on the discriminatory vendor list may not submit a bid on a contract to
provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the
construction or repair of a public building or public work, may not submit bids on leases of real property to a public
entity,may not be awarded or perform work as a contractor,supplier,subcontractor,or consultant under a contract with a
public entity, and may not transact business with any public entity in excess of 525,000.00 for a period of 36 months
from the date of being placed on the convicted vendor list or on the discriminatory vendor list.
Immigration and Nationality Act: The State of Florida will not intentionally award publicly-funded contracts to any
contractor who knowingly employs unauthorized alien workers, constituting a violation of the employment provisions
contained in 8 U.S.C. Section 1324a(e) [Section 274A(e) of the Immigration and Nationality Act ("INA")]. The Division
shall consider the employment by any contractor of unauthorized aliens a violation of Section 274A(e)of the INA.
Inspector General Cooperation: The Parties agree to comply with Section 20.055(5), Florida Statutes, for the
inspector general to have access to any records, data and other information deemed necessary to carry out his or her
duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5), Florida Statutes.
Lobbying: No funds received pursuant to this Agreement may be expended for lobbying the Legislature, the judicial
branch or any state agency.
Public Records: The mere receipt of public funds by a private entity, standing alone, is insufficient to bring that entity
within the ambit of the public record requirements. However, when a public entity delegates a public function to a private
entity, the records generated by the private entity's performance of that duty become public records.Thus, the nature
and scope of the services provided by a private entity determine whether that entity is acting on behalf of a public
agency and is therefore subject to the requirements of Florida's Public Records Law.
Record Retention: The contractor shall maintain and retain sufficient records demonstrating its compliance with the
terms of the Agreement for a period of at least five (5) years after final payment is made and shall allow the County,
FDEM, or its designee's access to such records upon request.
FCP.6
CAO
EXHIBIT I.B
FEDERAL CONTRACT PROVISIONS AND ASSURANCES
Acknowledgement of Terms, Conditions, and Grant Clauses
Certification
If the vendor subcontracts any of the work required under this Agreement, a copy of the signed subcontract
must be available to the Department for review and approval. The vendor agrees to include in the
subcontract that (1) the subcontractor is bound by the terms of this Agreement, (ii) the subcontractor is
bound by all applicable state and federal laws and regulations, and (iii) the subcontractor shall hold the
Department and Recipient harmless against all claims of whatever nature arising out of the subcontractor's
performance of work under this Agreement, to the extent allowed and required by law.The recipient shall
document in the quarterly report the subcontractor's progress in performing its work under this agreement.
For each subcontract,the Recipient shall provide a written statement to the Department as to whether the
subcontractor is a minority vendor as defined in Section 288.703, Fla. Stat.
On behalf of my firm, I acknowledge,the grant requirements identified in this document.
Vendor/Contractor Name Agnoli, Barber&Brundage,Inc.
Date -06 E OZ°
Authorized Signature 7"!'''
Dominick J. AmidP.E., President
EXHIBIT 1.8-1
CAO
EXHIBIT I
FEDERAL CONTRACT PROVISIONS AND ASSURANCES
CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY
and VOLUNTARY EXCLUSION
Contractor Covered Transactions
1) The prospective subcontractor of the Sub-recipient, Collier County, certifies, by submission of this
document, that neither it nor its principals is presently debarred, suspended, proposed for debarment,
declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department
or agency.
2) Where the Sub-recipient's subcontractor is unable to certify to the above statement,the prospective
contract shall attach an explanation to this form.
CONTRACTOR
Atnoli,Barber& Brundage, Inc.
f
By: ake.-44-
Signature
Dominick J. Amico,P.E.,President
Name and Title
7400 Trail Boulevard, Suite 200
Street Address
Naples, FL 34108
City, State, Zip
11-413-9991
DUNS Number
3//6-POZ,0
Date
Sub-Recipient Name: Collier County Board of County Commissioners
DEM Contract Number: H0309
FEMA Project Number: 4337-192-R
EXHIBIT I.B-2
S
COLLIER COUNTY
ANTICIPATED DISADVANTAGED, MINORITY, WOMEN OR VETERAN PARTICIPATION STATEMENT
Status will be verified. Unverifable statuses will require the Vendor/Prime Contractor to either provide a revised statement or provide source
documentation that validates a status. Contractor means an entity that receives a contract.
A. VENDOR/PRIME CONTRACTOR INFORMATION
PRIME NAME PRIME FEID NUMBER CONTRACT DOLLAR AMOUNT
Agnoli, Barber& Brundage, Inc. 59-22871.55
IS THE PRIME A FLORIDA-CERTIFIED DISADVANTAGED, VETERAN? Y @ IS THE ACTIVITY OF THIS CONTRACT,
MINORITY OR WOMEN BUSINESS ENTERPRISE
DBE? Y 0 CONSTRUCTION? Y ONDBE/MBE/WBE)? OR HAVE A SMALL DISADVANTAGED
BUSINESS 8A CERTIFICATION FROM THE SMALL BUSINESS MBE? Y ON CONSULTATION? 0 N
ADMINISTRATION? OR A SERVICE DISABLED VETERAN? WBE? Y Q OTHER? OY N
SDB 8A? Y 0
IS THIS SUBMISSION A REVISION? Y 0 IIF YES,REVISION NUMBER
B. IF PRIME HAS SUBCONTRACTOR OR SUPPLIER WHO IS A DISADVANTAGED MINORITY,WOMEN-OWNED,SMALL
BUSINESS CONCERN OR SERVICE DISABLED VETERAN,PRIME IS TO COMPLETE THIS NEXT SECTION
DBE,MBE,WBE SUBCONTRACTOR OR SUPPLIER TYPE OF WORK OR ETHNICITY CODE PERCENT OF CONTRACT
VET,SMB8A NAME SPECIALTY See Below) DOLLARS
MBE Robau and Associates,LLC Engineer HA 15%
WBE Quest Corporation of Public NMW 10%
America,Inc. Information
TOTALS:
C. SECTION TO BE COMPLETED BY PRIME VENDOR/CONTRACTOR
NAME OF SUBMITTER DATE TITLE OF SUBMITTER
Dominick J. Amico, P.E. 3/16/20 President
EMAIL ADDRESS OF PRIME(SUBMITTER) TELEPHONE NUMBER FAX NUMBER
amico@abbinc.com 239) 597-3111 239) 566-2203
NOTE:This information is used to track and report anticipated DBE or MBE participation in federally-funded contracts. The anticipated DBE or
MBE amount is voluntary and will not become part of the contractual terms. This form must be submitted at time of response to a
solicitation. If and when awarded a County contract,the prime will be asked to update the information for the grant compliance files.
ETHNICITY CODE
Black American BA
Hispanic American HA
Native American NA
Subcont.Asian American SAA
Asian-Pacific American APA
Non-Minority Women NMW
Other:not of any other group listed 0
D.SECTION TO BE COMPLETED BY COLLIER COUNTY
DEPARTMENT NAME COLLIER CONTRACT N(IFB/RFP or PO/REQ) GRANT PROGRAM/CONTRACT
ACCEPTED BY: DATE
EXHIBIT 1.8-3 CA0
EXHIBIT I
FEDERAL CONTRACT PROVISIONS AND ASSURANCES
LOBBYING CERTIFICATION
To be submitted with each bid or offer exceeding $100,000)
The undersigned [Contractor] certifies,to the best of his or her knowledge, that:
1. No Federal appropriated funds have been paid or will be paid,by or on behalf of the undersigned,to any person
for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer
or employee of Congress,or an employee of a Member of Congress in connection with the awarding of any Federal
contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative
agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract,grant,
loan, or cooperative agreement.
2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing
or attempting to influence an officer or employee of any agency,a Member of Congress,an officer or employee of
Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or
cooperative agreement, the undersigned shall complete and submit Standard Form- LLL, "Disclosure Form to
Report Lobbying," in accordance with its instructions.
3. The undersigned shall require that the language of this certification be included in the award documents for all
subawards at all tiers (including subcontracts, subgrants, and contracts under grants, loans, and cooperative
agreements)and that all subrecipients shall certify and disclose accordingly.
This certification is a material representation of fact upon which reliance was placed when this transaction was
made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction
imposed by 31, U.S.C. § 1352(as amended by the Lobbying Disclosure Act of 1995).Any person who fails to file
the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000
for each such failure.
The Contractor certifies or affirms the truthfulness and accuracy of each statement of its certification and
disclosure, if any. In addition, the Contractor understands and agrees that the provisions of 31 U.S.C. § 3801 et
seq., apply to this certification and disclosure, if any.
Agnoli, Barber&Brundage, Inc.
Contractor(Firm Name)
m
Signature of Co rtractor's Authorized Official
Dominick J. Amico, P.E.,President
Name and Title of Contractor's Authorized Official
Date--
EXHIBIT 1.8-4
CA O
A IOC CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY)
10/16/2020
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZEDREPRESENTATIVEORPRODUCER,AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER CONTACT
Brown&Brown Of Florida, Inc. NAME: Kristen Kozlow
FAX6611OrionBlvdSuite200JA/C.No.Ext):2392132011 NC
Fort Myers FL 34112 ADDREyADDRESS: kI<OZIOWf bbswfla.COm
INSURER(S)AFFORDING COVERAGE NAIC#
INSURER A:Sentinel Insurance Company,Ltd.11000
INSURED 349910
INSURER B:Hartford Accident and Indemnity Company 22357Agn740oli,TrailBa Blvd&
Brundage Inc.
INSURERC:Hartford CasualtyInsurance Company 294247400py
Suite 200 INSURERD:Scottsdale Insurance Company 41297NaplesFL34108
INSURER E:Westchester Fire Insurance Company 10030
INSURER F:
COVERAGES CERTIFICATE NUMBER:934648076 REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR ADDL SUBR
LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER
POLICY EFF POLICY EXP
MM/DD/YYW) (MM/DD/YYYY) LIMITS
A X COMMERCIAL GENERAL LIABILITY Y Y 21SBMVL1515 5/1/2020 5/1/2021 EACH OCCURRENCE 1,000,000
DAMAGE TO RENTEDCLAIMS-MADE X OCCUR
PREMISES Ea occurrence $1,000,000
MED EXP(Any one person) $10,000
PERSONAL&ADV INJURY $1,000,000
GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000
POLICY X 7E8T- LOC PRODUCTS-COMP/OPAGG $2,000,000
OTHER:Employee Benefits 2,000,000
B AUTOMOBILE LIABILITY Y Y 21UECDF2079 5/1/2020 5/1/2021 OMBIEDt SINGLE LIMIT $1,000,000EaaXANYAUTO
BODILY INJURY(Per person) $
OWNED SCHEDULED
AUTOS ONLY AUTOS BODILY INJURY(Per accident) $
X HIRED X NON-OWNED
PROPERTY DAMAGEAUTOSONLYAUTOSONLYPeraccident
A X UMBRELLA LIAB X OCCUR Y Y 21 SBMVL1515 5/1/2020 5/1/2021 EACH OCCURRENCE 2,000,000
EXCESS LIAB CLAIMS-MADE AGGREGATE 2,000,000
DED X RETENTION$1 n nnn
C WORKERS COMPENSATION Y 21WBCAGOV2P 5/1/2020 5/1/2021 X MUTEEMPLOYERS'LIABILITY Y/N STATUTE ER
ANYPROPRIETOR/PARTNER/EXECUTIVE
N E.L.EACH ACCIDENT $1,000,000OFFICER/MEMBEREXCLUDED? N/A
Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000
If yes,describe under
DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000
D Professional Liability JES0000033 5/1/2020 5/1/2021 Each Claim 2,000,000EEmploymentPracticesLiabilityG466337630045/1/2020 5/1/2021 Each Claim 1,000,000
DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required)
Engineering,Planning,Surveying&Landscape Architecture Firm
Certificate holders are included as additional insured with regards to General Liability Coverage on a Primary&Non-Contributory Basis including Ongoing andCompletedOperationsperfromSS00080405. General Liability Waiver of Subrogation in favor of certificate holder when agreed in written contract per formSS00080405. Certificate holders are included as additional insured&Waiver of Subrogation in favor of certificate holder with regards to Auto Liability when
agreed in written contract per form HA9916 0312. Waiver of Subrogation in favor of certificate holder when agreed in written contract per form WC000313.Umbrella is follow form.30 Days Notice of Cancellation,except for 10 days for Nonpayment.
See Attached...
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
Collier County Board of County Commissioners
3295 Tamiami Trail E.
Naples FL 34112 AUTHORIZED R
001 .7
1988-2015 ACORD CORPORATION. All rights reserved.
ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD
AGENCY CUSTOMER ID: 349910
LOC#:
ACCORD® ADDITIONAL REMARKS SCHEDULE Page 1 of
AGENCY
NAMED INSUREDBrown&Brown Of Florida, Inc.Agnoli,Barber&Brundage Inc.
7400 Trail BlvdPOLICYNUMBER
Suite 200
Naples FL 34108
CARRIER
NAIC CODE
EFFECTIVE DATE:
ADDITIONAL REMARKS
THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM,
FORM NUMBER: 25 FORM TITLE: CERTIFICATE OF LIABILITY INSURANCE
Collier County Board of County Commissioners,or,Board of County Commissioners in Collier County,or,Collier County Government,or,Collier CountyincludedasanadditionalinsuredundertheCommercialGeneralLiabilityandAutomobileLiabilityPoliciesonaPrimaryandnon-contributory basis if and to theextentrequiredbywrittencontract.
Contract#20-7678,Solana Road Stormwater Improvements Design Services
ACORD 101 (2008/01)
2008 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD