The URL can be used to link to this page

Agenda 12/13/2022 Item #16C 3 (Payment approval for Infinite Construction LLC)12/13/2022 EXECUTIVE SUMMARY Recommendation to approve payment of invoices in the amount of $32,245.46 to Infinite Construction, LLC, regarding Purchase Order No. 4500210113 under Agreement No. 19-7630 concerning the Barefoot Beach North Access Boardwalk & Pavilion Construction Project, and waiving liquidated damages in the amount of $6,205. (TDC Beach Park Facility Capital Fund (183)) (Project No. 80330) OBJECTIVE: To approve the payment of invoices totaling $32,245.46 to Infinite Construction, LLC concerning the Barefoot Beach North Access Boardwalk & Pavilion Construction Project under Agreement Number 19-7630. CONSIDERATIONS: This "after the fact" approval is requested to approve the payment of invoices from Infinite Construction, LLC Infinite for work performed under Purchase Order No. 4500210113 under Agreement No. 19- 7630 (the “Agreement”) in the amount of $32,245.46 for the Barefoot Beach North Access Boardwalk & Pavilion Construction Project. This issue arises because the project manager overseeing this work resigned from county employment without first initiating the proper contract time extensions. The contractor missed the January 2, 2022 Substantial Completion by only five (5) days, which under the terms of the Agreement gives rise to liquidated damages in the amount of $6,205. In addition, the county project manager’s failure to timely process a change order to enlarge the contract completion time also resulted in the contractor working beyond the established February 1, 2022, Final Completion date. Ultimately, the county accepted the completed construction project on March 30, 2022, with the contractor working diligently to provide services to the county’s benefit beyond the last established Final Completion date of February 1, 2022. Staff recommends that the Board waive the imposition of the liquidated damages since the contractor: (1) acted in good faith to perform under COVID impacts to both manpower and construction material availability, (2) performed the Agreement with a sense of urgency and due diligence, (3) would have avoided the potential for liquidated damages had the county’s project manager timely processed a change order, and (4) only missed meeting the Substantial Completion deadline by five days. Because the contractor provided services to the county’s benefit without any harm sustained by the public, staff requests that liquidated damages be waived and that approval be authorized to make payment for the final invoices for work completed upon a properly submitted final payment application with all required documentation submitted by the contractor to issue payment. FISCAL IMPACT: This project is funded in TDC Beach Park Facility Capital Fund (183), project 80330. LEGAL CONSIDERATIONS: This item has been reviewed by the County Attorney, is approved as to form and legality and requires majority vote for approval. -JAK GROWTH MANAGEMENT IMPACT: There is no Growth Management Impact associated with this action. RECOMMENDATION: To approve payment of invoices to Infinite Construction, LLC associated with the Barefoot Beach North Access Boardwalk & Pavilion Construction Project totaling $32,245.46 and waive the imposition of any accrued liquidated damages against the contractor as stated above. Clint Perryman, Project Manager, Facilities Management Division ATTACHMENT(S) 1. Exhibit D_Application for Payment (PDF) 2. Infinite Construction LLC After the Fact Barefoot Beach Pavilion (PDF) 3. PO 4500210113 (PDF) 4. [Linked] Agreement 19-7630 (PDF) 16.C.3 Packet Pg. 1176 12/13/2022 COLLIER COUNTY Board of County Commissioners Item Number: 16.C.3 Doc ID: 23788 Item Summary: Recommendation to approve payment of invoices in the amount of $32,245.46 to Infinite Construction, LLC, regarding Purchase Order No. 4500210113 under Agreement No. 19-7630 concerning the Barefoot Beach North Access Boardwalk & Pavilion Construction Project, and waiving liquidated damages in the amount of $6,205. (TDC Beach Park Facility Capital Fund (183)) (Project No. 80330) Meeting Date: 12/13/2022 Prepared by: Title: Operations Analyst, Senior – Facilities Management Name: Bendisa Marku 10/31/2022 3:24 PM Submitted by: Title: – Facilities Management Name: John McCormick 10/31/2022 3:24 PM Approved By: Review: Facilities Management John McCormick Director - Facilities Completed 10/31/2022 4:03 PM Procurement Services Ana Reynoso Level 1 Purchasing Gatekeeper Completed 10/31/2022 4:22 PM Procurement Services Sandra Herrera Additional Reviewer Completed 10/31/2022 4:36 PM Facilities Management Jennifer Belpedio Manager - Real Property Completed 11/01/2022 10:21 AM Facilities Management Dave Closas Additional Reviewer Completed 11/01/2022 11:25 AM Procurement Services Sue Zimmerman Additional Reviewer Completed 11/02/2022 1:48 PM Public Utilities Operations Support AmiaMarie Curry Additional Reviewer Completed 11/21/2022 11:33 AM Public Utilities Department Drew Cody Level 1 Division Reviewer Completed 11/28/2022 2:47 PM Public Utilities Department George Yilmaz Level 2 Division Administrator Review Completed 11/29/2022 12:37 PM Office of Management and Budget Debra Windsor Level 3 OMB Gatekeeper Review Completed 11/21/2022 12:25 PM Office of Management and Budget Susan Usher Additional Reviewer Completed 11/21/2022 4:29 PM County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 11/21/2022 4:39 PM County Attorney's Office Scott Teach Additional Reviewer Completed 11/23/2022 11:25 AM County Manager's Office Ed Finn Additional Reviewer Completed 12/05/2022 7:49 PM County Manager's Office Dan Rodriguez Level 4 County Manager Review Completed 12/06/2022 8:04 AM Board of County Commissioners Geoffrey Willig Meeting Pending 12/13/2022 9:00 AM 16.C.3 Packet Pg. 1177 Infinite Construction, LLC 6757 Dabney Street, Fort Myers , Fl 33966 Paulius Kirilinas Collier County Parks Administration 4500210113 11/12/2019 19-7630 80330.10 225,343.28 Paulius Kirilinas Owner 0.00 Dave Closas 201,146.24 $168,900.78 32,245.46100 100 3 - FINAL 03/30/2022 03/30/2022 24,197.04 08/24/2022 08/24/2022 0.00 0.00 Luis Santana Luis J. Santana II 8-25-22 16.C.3.a Packet Pg. 1178 Attachment: Exhibit D_Application for Payment (23788 : Payment of invoices to the Infinite Construction, LLC for Barefoot Beach North Access After the Fact Form Revised 06/17/2021 Instructions As per section 21 of the Procurement Manual, all purchases shall be consistent and in compliance with the Procurement Ordinance (2017-08). Should work be authorized or purchases made that is inconsistent with County policy, procedure, or contract terms, an After-the-Fact Procurement Form is required. This includes purchases made in advance of a Purchase Order, when a Purchase Order is required to authorize such activity, and purchases made under an expired contract, or for goods and services not covered by the current contract or purchase order. All such “After the Fact Procurements” will be reported to the County Manager. Requester Name: Division: Division Director: Vendor Name: Amount:Contract #: Purchase Order: Why is this deemed a non-compliant purchase? Choose one. Contract Ordinance Manual P-Card Other Corrective/Preventive Action: What action is being taken to prevent this violation from re-occurring? The requestor affirms that to the best of their knowledge the information provided in this document is true. Requested by: Signature: Date: Division Director: Signature: Date: Dave Closas Facilities Management John McCormick Infinite Construction, LLC $32,245.46 19-7630 4500210113 Details of Purchase: Explain the circumstances behind this purchase. This"After the Fact Form" is needed to approve the invoices for the Barefoot Beach North Access Boardwalk & Pavilion Construction Project totaling $32,245.46. The PM overseeing the project had resigned from the County and did not initiate the proper time extension before he had left the County. As a result, a change order to extend the contract time was not issued when the contract lapsed on 2/1/2022 and final completion was not reached on time. The vendor provided services past final completion date and the County needs approval to pay for work completed for this project. The construction has been completed and accepted by the County on March 30, 2022. Action Required: What are you asking to be done to remedy the situation, include list of invoices if applicable? Requesting the BOCC to approve the Infinite Construction, LLC final invoices in the amount totaling $32,245.46. Requesting the BOCC to waive the potential liquidated damages totaling 6,205. The Facilities Management Division will insure that the proper change order procedures are being initiated within the contract time frame. Dave Closas John McCormick ✔ ClosasDave Digitally signed by ClosasDave Date: 2022.09.26 14:01:00 -04'00' McCormickJohn Digitally signed by McCormickJohn Date: 2022.09.26 15:33:59 -04'00' 16.C.3.b Packet Pg. 1179 Attachment: Infinite Construction LLC After the Fact Barefoot Beach Pavilion (23788 : Payment of invoices to the Infinite Construction, LLC for Purchase Order number must appear on all related correspondence, shipping papers and invoices: Printed 11/22/2022 @ 10:20:03 Page 1 of 1183-116366-763100-80330.1 Collier County Board of County Commissioners Procurement Services Division Phone: 239-252-8407 Fax: 239-732-0844 Tax Exempt: 85-8015966531C-1 Collier County Board of County Commissioners Attn: Accounts Payable 3299 Tamiami Trl E Ste 700 Naples FL 34112-5749 OR email to: bccapclerk@collierclerk.com Send all Invoices to: VENDOR Terms and Conditions The VENDOR agrees to comply with all Purchase Order Terms and Conditions as outlined on the Collier County Procurement Services Division site: http://www.colliercountyfl.gov/home/showdocument?id=74077, including delivery and payment terms. Further the VENDOR agrees to: 1. Provide goods and services outlined in this Purchase Order with the prices, terms, delivery method and specifications listed above. 2. Notify department Immediately if order fulfillment cannot occur as specified. 3. Send all invoices to:Collier County Board of County Commissioners Attn: Accounts Payable 3299 Tamiami Trl E Ste 700 Naples FL 34112-5749 OR email to: bccapclerk@collierclerk.com The Purchase Order is authorized under direction of Collier County Board of County Commissioners by: Sandra Herrera, Director, Procurement Services Division Vendor # 125999 INFINITE CONSTRUCTION LLC 6749 IDLEWILD ST FT. MYERS FL 33966 Purchase order PO Number 4500210113 Date 03/29/2021 Contact Person Parks Admin Please deliver to: NORTH COLLIER REGIONAL PARK COLLIER COUNTY PARKS ADMINISTRATION 15000 LIVINGSTON RD NAPLES FL 34109 Delivery Date: 02/01/2022 Terms of Payment Net 30 Days Item Material Description Order Qty Unit Price Per Unit Net Value 00010 CON Boardwalk & Pavilion Replacement 225,343.28 EA 1.00 225,343.28 Barefoot Beach North Access Boardwalk & Pavilion Replacement *** Item partially delivered *** 225,343.28Total net value excl. tax USD 16.C.3.c Packet Pg. 1180 Attachment: PO 4500210113 (23788 : Payment of invoices to the Infinite Construction, LLC for Barefoot Beach North Access Boardwalk) 12/13/2022 EXECUTIVE SUMMARY Recommendation to approve payment of invoices to Stanley Consultants, Inc., regarding Purchase Order Number 4500209336 totaling $4,411.00, pertaining to the Barefoot Beach North Access Boardwalk & Pavilion. (Project No. 80330) OBJECTIVE: To approve payment of invoices to Stanley Consultants, Inc., regarding Purchase Order Number 4500209336 totaling $4,411.00, pertaining to the Barefoot Beach North Access Boardwalk & Pavilion. CONSIDERATIONS: This "after the fact" approval is requested to approve the payment of invoices from Stanley Construction, Inc. for work performed under Purchase Order Number 4500209336 in the amount of $4,411.00 for the Barefoot Beach North Access Boardwalk & Pavilion (the “Project”). The project manager overseeing the Project resigned from the County and did not initiate the proper time extension before leaving county employment. As a result, a change order extending the contract time was not issued prior to the established final completion date of February 5, 2022. The vendor successfully provided services beyond that final completion date thus necessitating staff’s request to approve the final invoices for the completed work. The post design services and construction were completed and accepted by the County on April 5, 2022. FISCAL IMPACT: Funds are available in the TDC Beach Park Facilities Fund 183 with in Project 80330 on Purchase Order 4500209336. There is no additional f iscal i mpact associated with this action. LEGAL CONSIDERATIONS: This item has been reviewed by the County Attorney, is approved as form and legality and requires majority vote for approval.-SRT GROWTH MANAGEMENT IMPACT: There is no Growth Management Impact associated with this action. RECOMMENDATION: To approve payment of invoices to Stanley Consultants, Inc., regarding Purchase Order Number 4500209336 totaling $4,411.00, pertaining to the Barefoot Beach North Access Boardwalk & Pavilion. Clint Perryman, Project Manager, Facilities Management Division ATTACHMENT(S) 1. Stanley Consultants Invoice 0238734 (PDF) 2. Stanley Consultants Invoice 0237940 (PDF) 3. ATF Stanley Consultants, Inc (PDF) 16.C.4 Packet Pg. 1181 12/13/2022 COLLIER COUNTY Board of County Commissioners Item Number: 16.C.4 Doc ID: 23789 Item Summary: Recommendation to approve payment of invoices to Stanley Consultants, Inc., regarding Purchase Order Number 4500209336 totaling $4,411.00, pertaining to the Barefoot Beach North Access Boardwalk & Pavilion. (Project No. 80330) Meeting Date: 12/13/2022 Prepared by: Title: Operations Analyst, Senior – Facilities Management Name: Bendisa Marku 11/15/2022 12:00 PM Submitted by: Title: – Facilities Management Name: John McCormick 11/15/2022 12:00 PM Approved By: Review: Facilities Management John McCormick Director - Facilities Completed 11/15/2022 12:54 PM Procurement Services Ana Reynoso Level 1 Purchasing Gatekeeper Completed 11/15/2022 1:18 PM Facilities Management Jennifer Belpedio Manager - Real Property Completed 11/15/2022 3:03 PM Procurement Services Sue Zimmerman Additional Reviewer Completed 11/21/2022 10:23 AM Procurement Services Bendisa Marku Additional Reviewer Skipped 11/21/2022 10:26 AM Public Utilities Operations Support AmiaMarie Curry Additional Reviewer Completed 11/21/2022 1:28 PM Public Utilities Department Drew Cody Level 1 Division Reviewer Completed 11/23/2022 12:32 PM County Attorney's Office Scott Teach Additional Reviewer Completed 11/23/2022 1:59 PM Public Utilities Department George Yilmaz Level 2 Division Administrator Review Completed 11/28/2022 9:44 AM County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 11/28/2022 4:27 PM Office of Management and Budget Susan Usher Additional Reviewer Completed 11/30/2022 5:14 PM Office of Management and Budget Debra Windsor Level 3 OMB Gatekeeper Review Completed 12/01/2022 10:11 AM County Manager's Office Ed Finn Additional Reviewer Completed 12/05/2022 7:48 PM County Manager's Office Dan Rodriguez Level 4 County Manager Review Completed 12/06/2022 8:22 AM Board of County Commissioners Geoffrey Willig Meeting Pending 12/13/2022 9:00 AM 16.C.4 Packet Pg. 1182 Invoice Total $1,789.00 Collier County Board of County Commissioners Clerk's Finance Department 3299 Tamiami Trail E Suite 700 Naples, Florida 34112-5749 May 23, 2022 Project No:29680.02.00 Invoice No:0238734 1641 Worthington Road, Suite 400 West Palm Beach, FL 33409 Attention: Jim Morton, Dave Closas For: Contract No: 18-7432ST Purchase Order No: 4500209336 Collier County Project No: 80330 Barefoot Beach Post Design Services Professional Services from April 3, 2022 to April 30, 2022 Package 000 Post Design Services Deliverable WPST1 Construction Admin Professional Personnel Hours Rate Amount Senior Project Manager Santana, Luis 10.00 201.00 2,010.00 Totals 10.00 2,010.00 Total Labor 2,010.00 Billing Limits Current Prior To-Date Total Billings 2,010.00 6,606.00 8,616.00 Limit 8,395.00 Adjustment -221.00 $1,789.00Total this Deliverable Deliverable WPST2 CCSL Permit Billing Limits Current Prior To-Date Total Billings 0.00 2,613.00 2,613.00 Limit 4,381.00 Remaining 1,768.00 0.00Total this Deliverable Deliverable WPST3 FWCC Permit Billing Limits Current Prior To-Date Total Billings 0.00 2,412.00 2,412.00 Limit 4,604.00 Remaining 2,192.00 16.C.4.a Packet Pg. 1183 Attachment: Stanley Consultants Invoice 0238734 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Project 023873429680.02.00 Barefoot Beach Post Design Services Invoice 0.00Total this Deliverable $1,789.00Total this Package Package EXP Expenses Deliverable 00EXP Expenses Billing Limits Current Prior To-Date Total Billings 0.00 0.00 0.00 Limit 1,136.00 Remaining 1,136.00 0.00Total this Deliverable 0.00Total this Package Package SUB Subconsultant Deliverable 00SUB Sub 01 - Passarella & Assoc Billing Limits Current Prior To-Date Total Billings 0.00 20,320.00 20,320.00 Limit 34,800.00 Remaining 14,480.00 0.00Total this Deliverable 0.00Total this Package $1,789.00TOTAL THIS INVOICE Outstanding Invoices Number Date Balance 0237940 04/15/2022 2,622.00 Total 2,622.00 If you have any questions regarding this invoice, please contact Luis Santana at 561-584-8717 or Teresa at 563-264-6604. REMIT TO: Stanley Consultants | Attn: Cash Receipts | 225 Iowa Ave, Muscatine, IA 52761 To set up payment via ACH, please contact AccountingMailbox@stanleygroup.com. Page 2 16.C.4.a Packet Pg. 1184 Attachment: Stanley Consultants Invoice 0238734 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Project 023873429680.02.00 Barefoot Beach Post Design Services Invoice 10:18:56 AMInvoice 0238734 Dated 05/23/2022Stanley Consultants, Inc. Monday, May 23, 2022Billing Backup Package 000 Post Design Services Deliverable WPST1 Construction Admin Professional Personnel Hours Rate Amount Senior Project Manager 07661 Santana, Luis 04/04/2022 6.00 201.00 1,206.00 Working on As-built plans. 07661 Santana, Luis 04/05/2022 4.00 201.00 804.00 Working on As-built and coordinating project closeout with the County PM. Totals 10.00 2,010.00 Total Labor 2,010.00 $2,010.00Total this Deliverable Total this Package $2,010.00 $2,010.00Total this Project $2,010.00Total this Report Page 3 16.C.4.a Packet Pg. 1185 Attachment: Stanley Consultants Invoice 0238734 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Invoice Total $2,622.00 Collier County Board of County Commissioners Clerk's Finance Department 3299 Tamiami Trail E Suite 700 Naples, Florida 34112-5749 April 15, 2022 Project No:29680.02.00 Invoice No:0237940 1641 Worthington Road, Suite 400 West Palm Beach, FL 33409 Attention: Miguel Flores, Jim Morton, Dave Closas For: Contract No: 18-7432ST Purchase Order No: 4500209336 Collier County Project No: 80330 Barefoot Beach Post Design Services Professional Services from December 5, 2021 to April 2, 2022 Package 000 Post Design Services Attention: Michael Cherbini For: Contract No: 18-7432ST Purchase Order No: 4500209336 Collier County Project No: 80330 Barefoot Beach Post Design Services Deliverable WPST1 Construction Admin Professional Personnel Hours Rate Amount Senior Project Manager Santana, Luis 10.00 201.00 2,010.00 Totals 10.00 2,010.00 Total Labor 2,010.00 Billing Limits Current Prior To-Date Total Billings 2,010.00 4,596.00 6,606.00 Limit 8,395.00 Remaining 1,789.00 $2,010.00Total this Deliverable Deliverable WPST2 CCSL Permit Billing Limits Current Prior To-Date Total Billings 0.00 2,613.00 2,613.00 Limit 4,381.00 Remaining 1,768.00 0.00Total this Deliverable 16.C.4.b Packet Pg. 1186 Attachment: Stanley Consultants Invoice 0237940 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Project 023794029680.02.00 Barefoot Beach Post Design Services Invoice Deliverable WPST3 FWCC Permit Billing Limits Current Prior To-Date Total Billings 0.00 2,412.00 2,412.00 Limit 4,604.00 Remaining 2,192.00 0.00Total this Deliverable $2,010.00Total this Package Package EXP Expenses Deliverable 00EXP Expenses Billing Limits Current Prior To-Date Total Billings 0.00 0.00 0.00 Limit 1,136.00 Remaining 1,136.00 0.00Total this Deliverable 0.00Total this Package Package SUB Subconsultant Deliverable 00SUB Sub 01 - Passarella & Assoc SubConsultants Subconsultant 04/02/2022 Passarella & Associates Inc.THROUGH 03/31/2022 612.00 Total SubConsultants 612.00 612.00 Billing Limits Current Prior To-Date Total Billings 612.00 19,708.00 20,320.00 Limit 34,800.00 Remaining 14,480.00 $612.00Total this Deliverable $612.00Total this Package $2,622.00TOTAL THIS INVOICE If you have any questions regarding this invoice, please contact Luis Santana at 561-584-8717 or Teresa at 563-264-6604. REMIT TO: Stanley Consultants | Attn: Cash Receipts | 225 Iowa Ave, Muscatine, IA 52761 To set up payment via ACH, please contact AccountingMailbox@stanleygroup.com. Page 2 16.C.4.b Packet Pg. 1187 Attachment: Stanley Consultants Invoice 0237940 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Project 023794029680.02.00 Barefoot Beach Post Design Services Invoice 2:33:24 PMInvoice 0237940 Dated 04/15/2022Stanley Consultants, Inc. Friday, April 15, 2022Billing Backup Package 000 Post Design Services Deliverable WPST1 Construction Admin Professional Personnel Hours Rate Amount Senior Project Manager 07661 Santana, Luis 03/30/2022 8.00 201.00 1,608.00 Working on punch list and permit closeout. 07661 Santana, Luis 04/01/2022 2.00 201.00 402.00 Coordinating with County PM and permit closeout. Totals 10.00 2,010.00 Total Labor 2,010.00 $2,010.00Total this Deliverable Total this Package $2,010.00 Package SUB Subconsultant Deliverable 00SUB Sub 01 - Passarella & Assoc SubConsultants Subconsultant AP 4289789 04/02/2022 Passarella & Associates Inc. / THROUGH 03/31/2022 612.00 Total SubConsultants 612.00 612.00 $612.00Total this Deliverable Total this Package $612.00 $2,622.00Total this Project $2,622.00Total this Report Page 3 16.C.4.b Packet Pg. 1188 Attachment: Stanley Consultants Invoice 0237940 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Stanley Consultants, Inc.Invoice number 8A Invoice date 04/11/2022 Page 1 03/07/2022 Gopher tortoise permit renewal 0.50 120.00 60.00 03/03/2022 Gopher tortoise permit extension review 1.25 120.00 150.00 Environmental Specialist - Office 03/31/2022 Reviewed FWCC gopher tortoise compliance requirements 1.00 201.00 201.00 03/30/2022 Reviewed FWCC gopher tortoise compliance requirements 1.00 201.00 201.00 Senior Project Manager - Office Hours Rate Billed Amount Task subtotal 612.00 Task 5.A General Consultation and Meetings 99.A Reimbursables 0.00 0 26.50 26.50 0.00 8.A Gopher Tortoise Relocation 4,100.00 65 2,663.50 2,663.50 0.00 7.A FWCC 10 or Fewer Burrow Gopher Tortoise Relocation Permit 5,400.00 60 3,219.75 3,219.75 0.00 6.A Updated Gopher Tortoise Burrow Survey 2,500.00 67 1,680.00 1,680.00 0.00 5.A General Consultation and Meetings 3,500.00 68 1,768.50 2,380.50 612.00 4.A Gopher Tortoise Management Plan 3,200.00 95 3,054.50 3,054.50 0.00 3.A Gopher Tortoise Burrow Survey 2,700.00 99 2,663.50 2,663.50 0.00 2.A Planting and Restoration Plan 3,400.00 84 2,868.75 2,868.75 0.00 1.A FLUCFCS Map 1,800.00 98 1,763.00 1,763.00 0.00 Total 26,600.00 19,708.00 20,320.00 612.00 Professional Services Due This Invoice: 612.00 Description Contract Amount Percent Complete Prior Billed Total Billed Current Billed 13620 Metropolis Avenue Suite 200 Fort Myers, FL 33912 239-274-0067 For services rendered in connection with the Barefoot Beach Boardwalk and Shelter Replacement (“Project”) located in Section 6, Township 48 South, Range 25 East, Collier County, Florida. Professional services through March 31,2022 In Account With Stanley Consultants, Inc. 1641 Worthington Road, Suite 400 West Palm Beach, FL 33409 Barefoot Beach Boardwalk & Shelter Replacement Project #19SCC3113 (Invoice 8A)April 11, 2022 FINAL INVOICE 16.C.4.b Packet Pg. 1189 Attachment: Stanley Consultants Invoice 0237940 (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North After the Fact Form Revised 06/17/2021 Instructions As per section 21 of the Procurement Manual, all purchases shall be consistent and in compliance with the Procurement Ordinance (2017-08). Should work be authorized or purchases made that is inconsistent with County policy, procedure, or contract terms, an After-the-Fact Procurement Form is required. This includes purchases made in advance of a Purchase Order, when a Purchase Order is required to authorize such activity, and purchases made under an expired contract, or for goods and services not covered by the current contract or purchase order. All such “After the Fact Procurements” will be reported to the County Manager. Requester Name: Division: Division Director: Vendor Name: Amount: Contract #: Purchase Order: Why is this deemed a non-compliant purchase?Choose one. Contract Ordinance Manual P-Card Other Details of Purchase: Explain the circumstances behind this purchase. Action Required: What are you asking to be done to remedy the situation, include list of invoices if applicable? Corrective/Preventive Action: What action is being taken to prevent this violation from re-occurring? The requestor affirms that to the best of their knowledge the information provided in this document is true. Requested by: Signature: Date: Division Director: Signature: Date: 16.C.4.c Packet Pg. 1190 Attachment: ATF Stanley Consultants, Inc (23789 : Payment of invoices to the Stanley Consultants, Inc for Barefoot Beach North Access CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDAI ("Owner") hereby contracts with Infinite Construction, LLC ("Contractor") of 6749 Idlewild St., Fort Myers, FL 33966, a Limited Liability Company, authorized to do business in the State of Florida, to perform all work ("Work") in connection with Barefoot Beach North Access Boardwalk and Pavilion Replacement, Invitation to Bid No. 19=7630 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Stanley Consultants, Inc., the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount"), in accordance with the terms of this Agreement: Two Hundred Twenty -Five Thousand Three Hundred Forty -Three Dollars and Twenty -Eight Cents ($225,343.28) Section 4. Bonds. A. If applicable, the Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit B-1 and B-2, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www.fms.treas.gov/c570/c570,html#certified. Should the Contract Amount be less 1 Construction Services Agreement: Revised 072118 C.q,C than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the suretyfor any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liquidated Damages. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The "Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date, No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within ninety (90) calendar days from the Commencement Date (herein "Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within thirty (30) calendar days after the date of Substantial Completion, Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, One thousand Two -hundred Forty-one dollars ($1,241) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion, The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday to) 2 Construction Services Agreement: Revised 072118 or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendarldays or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non -delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed upon, attached hereto and made a part of this Agreement for Solicitation 19-7630 Barefoot Beach North Access Boardwalk and Pavilion Replacement. Exhibit Exhibit A-1: A-2: Contractor's Bid Schedule 3 Construction Services Agreement: Revised 072118 CA�� Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions ® Applicable ❑ Not Applicable The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 19=7630 Barefoot Beach North Access Boardwalk and Pavilion Replacement. The complete contract documents, including Addendum with attachments, are available on the County's on-line bidding system: https://www.bidsync.com/ bidsync-cas/, which the parties agree comprise the final integrated agreement executed by the parties. Sections corresponding to any checked box (®) expressly apply to the terms of this Agreement and are available through the County 's on-line bidding. ❑Exhibit J: Technical Specifications ❑Exhibit K: Permits ®Exhibit L: Standard Details ®Exhibit M: Plans and Specifications prepared by Stanley Consultants, Inc. Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, FL c/o Collier County Parks & Recreation 15000 Livingston Road I Naples, FL 34109 Attn: Michael Cherbini, Contract Administrator/Project Manager Phone: 239-2524020 Email: Michael Cherbini a(�coil iercountyfl.gov B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Infinite Construction, LLC 6749 Idlewild St. Fort Myers, FL 33966 Attn: Paulius Kirilinas, Owner Phone: (239) 826-1268 Email: mflores.inficon(cbgmail. com C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. 4 Construction Services Agreement: Revised 072118 C(+. Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreement. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State A Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. 5 CAO Construction Services Agreement: Revised 072118 Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. 6 0 Construction Services Agreement: Revised 072118 CAO IN WITNESS WHEREOF, the parties have executed this Agreement on the dateks) indicated below. CONTRACTOR: TWO WITNESSES/; Infinite Construction, LLC to FIRST WIT ESS By: PrMt Nam �6rt1ic!!=, k'r� .,,tar' OS��d•%1 Iq � Print Name and Title Date SECOND WITNESS Print Name Date; 0��19 Crystal t •.KionYbl;'Cleik of Courts & Cori ttollor BY: Attest asto•Ghairrrian's signature only. Approved as to Form and Legality: Print Name OWNER: BOARD OF COUNTY COMMISSIONERS OF COLLIER Cq,c;rgN FLORIDA BY: am L. McDaniel Jr. Tate irman i %,,`Z�ILc \ Construction Services Agreement: Revised 072118 CAO EXHIBIT Awl' CONTRACTOR'S BID SCHEDULE (FOLLOWING THIS PAGE) 8 Construction Services Agreement: Revised 072118 CAU J' p N n N O N O) N rm-i OMi u N O) N N mN O) V O O O low ti� N In N Vl H In m m N w w w LU V) g m a, j V ' Q m tC ° W L z to Q u w w zCO ° z Q s w O ti j O a w 4 . O m vi N F d ez 0 ".. Z O z z Y d 00 w t�iJ 0 3 w w '.' O cl Z n. a w 0 Z L w w O V �S O p z wK O J ¢: O ra Q 4/1 w F Aj Z o N M � 2 m } d w CW ' ' Q .. a . A' A: z ;i a O z CAU EXHIBIT A-2: CONTRACTOR'S BID SUBMITTAL FORMS AND ADDENDUM (FOLLOWING THIS PAGE) 9 Construction Services Agreement: Revised 072118 CAv Page I of 1 7eY 014.14ty Adm<nistrawe Services WSW Purchasing ADDENDUM #1 Memorandum Email: jimflanagan@colliergov.net Telephone: (239) 252-8946 Date: July 19, 2019 From: Jim Flanagan, Procurement Strategist To: Interested Parties Subject: Addendum #1 — 19-7630 Barefoot Beach North Access Boardwalk & Pavilion Replacement This addendum has been issued for the following items identifying changes, deletions, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike -through. The extent of the rape rail fence along the vegetation line was clarified per revised plan, attached. Y Attached: 19-763Q —Addendum #1 —Barefoot Beach Site Plan Sheet 4 of 9 RevB 7-17-19 Indicating extent of rope -rail fence line requiring removal and replacement Attached: 19-7630 -Addendum #1 -Pre-bid Meeting Minutes and Sign -in sheets The building permit has been initially submitted to the Growth Management Division under Permit PRBD20190729196. y The Engineer of Record (EOR) will apply for the CCSL permit and obtain gapher tortoise survey, If gopher tortoise relocation is required, it will be handled under the EOR. o Exotic removal and replanting for Vegetation Inventory for the CCSL permit work is by others. Please include the Grant -Required 13id Dorms completed and signed and uploaded with your bid submittal on BidSync. 1-6 Acknowledgement of I`erms, Conditions and Grant Clauses 1-7 Certification Regarding Debarment, Suspension; Ineligibility, and Voluntary Exclusion 1-8 Collier County Anticipated Disadvantaged, Minority, Women or Veteran Participation Statement 1-9 Lobbying Certification Question and Answer period closes July 23. All, questions to date have been answered. Questions and Answers are hereby incorporated into the bid. Please acknowledge receipt of this Addendum with your bid proposal. Signature I3 idder if you require additional information, please post a question on the Online Bidding site or contact me using the above contact information, Page I of 1 AArcouvity Administrative Services Division Purchasing ADDENDUM #2 Memorandum Email: jimflanagan@colliergov,net Telephone: (239) 25M946. Date: July 24, 2019 From: Jim Flanagan, Procurement Strategist To: Interested Parties Subject: Addendum #2 — 19-7630 Barefoot Beach North Access Boardwalk & Pavilion Replacement This addendum has been issued far the following items identifying changes, deletians, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike -through. The extent of the rope rail fence along the vegetation line was clarified per revised plan, attached. Attached: 19-7630 -Addendum #2 —Proposed Park Pedestrian Access Exhibit o Contractor Laydown area and Pedestrian Access defined. i> Q&A Clarification: If any vegetation is removed during the course of construction, it shall be replaced in kind by the contractor. No additional plantings from the existing condition prior to construction are required by the contractor at this time. The Question and Answer period has closed. All questions to date have been answered. Questions and Answers are hereby incorporated into the bid. Please acknowledge receipt of. this Addendum with your bid proposal. •i:��J.F6z.r3 Signature t(1'�`ll � #`; 4 ryv� c: �-t�•LA f`'!' Cs!''i � � ,1-.c,,.__ Bidder if you require additional information, please post a question on the Online bidding site or contact me using the above contact information. Admii iI U-ZIPM S PrtScUTeme It Meeting Minutes S U Rod C { i O n . 147830 BIefool flaach Naih Access Boa,dNaOc antl Pavdlon Replacamon: [� Selection Committee [� Negotiation Meeting Other: Pre -Bid Meeting Date: 07-11-19 Start Time: 10:07 am LoGatian: procurement Services Conf Room A Commiffee Members (Voting) In AtCendance: Absent: Advisors/Staff: Jim Flanagan/CCPS Felicia Kirby/Parks Michael Cherbini/Parks Wis Sanlanel5lenley CensultantslHOR Purpose: Solicitation Pre -Bid Meeting SOLICITATION # 19-7630 Barefoot Beach North Access Boardwalk and Pavilion Replacement Discussion/Action: Bid Due Date: Thursday, August 01, 2019 a 3:00 pm Last Day for Questions: Tuesday July 23, 2019 @ 5:00 pm Answers to Questions: Thursday July 25, 2019 Completion; 90 days to Substantial, 30 days to final, 120 days overall, liquidated Damages will be $1241 per calendar day (FDOT Standard) All Bid Questions must be submitted on-line - No Questions will be answered during pre -bid meeting Bid to be submitted on Collier County Electronic Bid System. Subsequent to Pre -Bid Meeting, attendees were invited to tour site to view the site conditions. Recommendations: 1. All questions and discussions to be submitted on line by contractors, All answers will be provided on-line only Adjourn Time/Facilitator; 10:44 am /Jim Flanagan Meeting Minutos Form CAO Rev. 11/16/201 e ATTENDANCE SHEET PRE -BID MEETING Date: Q7-i1-�.9 SGLICITATI0N # 19-7630 BaretQot Beach North Access Boardwalk and Pauition Replacement COUNTY DEPARTMENTS REPRESENTEd: Name_ — Name Name Name ,) �0 Name '►��1uLa Name ►f��Tii� Name Name Name Name Name DIVISION �� J ��IltS DIVISION S - 'o DIVISION sC��, c©� su l��'in � a1�. DIVISION Pb 0,)t f� DIVISION DIVISION DIVISION DIVISION DIVISION DIVISION DIVISION DIVISION DIVISION DIVISION CAU ATTENDANCE SHEET PRE"DID MEETING Date: 07-1I -19 SOLICI I /A I MJ11 # 19-7830 Barefoot Beach North Access Uoardwalk and Pavilion Replacement PLEASE PRINT YOUR NAME: UK NAME: Comq'anv Name Mailing Address ;8 per- c^r;,,�r;; r' � .� ; � •� City, State ZIP FAX Number: (� �r ) �`�' • � 'f<� Email address: YC3UR NAMi✓: Company Name Mailing Address City, State Telephone: FAX Number; Email address: ZIP Company Name Mailing Address City, State Telephone: ( ) Email address. YOUR NAME: Company Name Mailing Address City, State ZIP Telephone: (_ ) ZIP FAX Number. ( ) Email address. cAo ATTENDANCE SHEET PRE -BID MEETING Date: V/-L 19 SOLICITATION # 19-7630 Barefoot Beach North Access Boardwalk and Pavilion Replacement PLEASE PRINT YOUR NAME:,1-�� -� YOUR NAME: Company Name Mailing Address City, Sta ZIP Telephone: {��) Company Name Mailing Address City, State Telephone: ( ) FAX Number: ( � ) `� FAX Number: Email address: Email address: YOUR NAME: Company Name Mailing Address City, State Telephone: zIP FAX Number: ( ) Email address: YOUR NAME: Company Name Mailing Address City, State Telephone: ZIP ZIP FAX Number: ( ) Email address: cao ATTENDANCE SHEET PRE -BID MEETING Date: Ol-1I-19 SULICITATIUN # 19-i630 Barefoot Beach North Access Boardwalk and Pavilion Replacement PL�AS� PRICdT YOUR NAME: ,L` ��. � � YOUR NAME: Company Name Mailing Address City, State ZIP Company Name Mailing Address City, State Telephone: Email address: Email address: Yt3UR NAME: Company Name Mailing Address City, State Telephone: { ) FAX Number: Email address: zzP YtJUR NAME: Company Name Mailing Address City, State Telephone: FAX Number: Email address: ZIP ZIP c�c ATTENDANCE SHEET PRE -BID MEFTiNG Date: 07-11-19 �OUtA 1 TI®N It 19d7630 Barefoot each North AcCeSu Boardwalk and Pavilion Replacement �/ t� PLPAS� PRINT YOUR NAME: t'��,�� i}dYs YOUR NAME: Company Name( Mailing Address City, S ate Telephone: (� �� ) �-`�� ' 1'i�f ✓� Company Name Mailing Address City, State Telephone: Email address: k6t� �sC�. �,Ll� � rvltt' �cx�w� Email address: YOUR NAME: Company Name Mailing Address City, State Telephone: FAX Number: ( Email address: ZIP YOUR NAME: Company Name Mailing Address City, State Telephone: FAX Number: Email address: zIP ZIP n BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA Barefoot Beach North Access Boardwalk and Pavilion Replacement BID NO. 194630 Full Name of Bidder Main Business Place of Business (�-i�lr-; §<'1%]rr.0 i lit -� . t-�,f •r n" z�r�c r� � Y , � � «�.� - �.1 Telephone No. Fax 140.1 State Contractor's License # State of Florida Certificate of Authority Document Number Federal Tax Identification Number __A11Z kA0 Cage Code To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA (hereinafter called the Owner) The undersigned, as Bidder declares that the only person. or parties interested :in this .Biel as principals are those names} herein; that this Bid is submitted without collusion with any other person, i`irm or corporation; that it has carefully examined the location of the proposed Work, the proposed form of Agreement and all other Contract Documents and Bonds, and the Contract Drawings and Specifications. Bidder proposes, and agrees if this Bid. is accepted, Bidder will execute the Agreement included in the Bidding Documents; to provide all necessary machinery, tools, apparatus and other means of construction, including utility and transportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract, and to do all other things required of the Contractor by the Contract Documents, and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall he provided in no more than two decimal points, and in the case where further decimal points are inadvertently provided, rounding to two decimal points wilt be conducted by Procarement Services Division staff. THIS .FORM MUST BE COMPLETED OR BID SHALL B.E DEEIVIED NON-I2E01'ONSIV[ All Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this }aid specifications, including compliance with Florida Statute 255.20 to provide lumber, timber and other forest products produced and manufactured in the State of Florida as .long as the price, fitness and quality are equal. Exceptions (when equals are acceptable) may be requested by completing the Material Manufacturer Exception List below. If an exception for a manufacturer and/or material is proposed and listed below and is not approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in the specification. Acceptance of this form does not constitute acceptance of material proposed on this list. Complete and sign section. A nR B. Section A (Acceptance of all manufactures and materials in Bid specifications) On behalf of my firm, I confirm that we will use all manufacturers and materials as specifically ouflfned in the Bid specifications. Signahire: Section .B (Exception requested to Bid specifications manufacturers and materials) EXCL:PTI:UN MATERIAL 1. 2. 3. 4. S. Please insert additional pages as necessary. Signature: Date: EXCEPTION MANUFACTURER tsj !t'-i C'AC7 FORM 47 LIST.:OF MAJOR SUBCONTRACTORS... THIS .I TST MUST [3E COM.PLETED OR BID IVIAY BE DEEMED NO.N-12ESPONSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories outlined in the requirements of the [aid specifications. The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the major categories fisted herein are "qualified" (as defined in Ordinance 2017-08 and Section 15 of Instructions to Bidders) and meet all legal requirements applicable to and necessitated by the Contract Documents; including, but not limited to proper licenses, certifications, registrations and insurance coverage. The Owner reserves the right to disqualify any Bidder who includes non -compliant or non -qualified Subcontractors in its bid offer. Further, the Owner may direct the Successful Bidder to remove/replace any Subcontractor, at no additional cost to Owner, which is found to be non -compliant with this requirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents, the Successful Bidder shall identify all Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified as noted above. Major Category of Work Subcontractor and Address t. Sitework/ ilex � 2. Framing and Carpentry ), 3. Aluminum Fabric Structures �( r, �;1 { „nv... r.. ,'fir! gin; 4. Sitrnage 51�1 5. Identify other subcontractors) that represent more than 10% of price or that affect the critical path of the schedule Company: 1•n ;n;-�? �.R.�,n<_,��-f�r�.l✓,��_) � _____ Signature: `'' Date:1. t 0LI...LVI FORMS - STATEMENT OF"EXPERIENCE OF:B PDER The Bidder is required to state below what work of similar magnitude completed within the last five (5) years is a judge of its experience, skill and business standing and of its ability to conduct the work as completely and as rapidly as required under the terms of the Agreement. 3. ..ter. ,fy.{ ijIlit�;`C� Srart'i't# [Cst_ �tGt 1;d" �•sil—;fiic,�, (Iqq projec .name) ' (project owner) f location) ��Wr, ( (Owner's address) 7Fia. L' I .. 7 )!. F \i _.__13.3. ice .• �. �-c,?(i��'Yef ';t7fira lc<tl �� c.�`Ik• 1 1 ' s•'t" � (project d9 rip ion�� ' ! (Owners contact person) (title) ( y 1'"i $ PDA (l. Frl' sk-�,� riti if'iM.Jz''+. !_...d;,ic�i'% f r ... 'f':r'�:}C�'r''1--�•i" { •C'{C.'t;! (project start/completion dates) (contract value) (phone) (email) ` t'i(l{t �,%It'c:�J.0 i"C%1�!. 1''iY:" }�t7.''S�k/ua�Itilt'�' ( r^.11,r�t—� (_.'Xlrltit,_(._�_1_'l�.r{ ,%,s ( L�t�fiiZl__,.._i.`y.�•?r'Yl�'..j (project name— .T (project owner) 1 %J q ��?`�.) 1 r�.�rtr" li="�`�ai"C�� f•1l� (, :r1"�jr;Ir'��,�',�_=✓=�=r...1_ �1.�r.. ..it::•<i �,re2c.�' Is.�:y>?�`=, �rL_..._'J"��L't'"l 'i'i^ Owner's address) (project location) ! J ..>:f{ .(�. ( !� f!' ,,j l� Y117e0i P�I}��1i£'lr`i+t�+' i title (project description) s;,r.{,,c y; ,`t-<:rT z:u a -( (Owner's contact person) ( ) r 1 $ `""aze :h r� i'`l LACX (project start/ omptetion dates) (contract value) (phone) (email) (project name) (project owner) Q CI Ll mil' � S t�,lt' • t?"t'1 • •Ivi �!Y•.}`1:;i � , f � �{ I�1 { __ •c v� 'tGt %r"Y�n tl �� :ems , •�cl �'i- r�'u\�'1,� 1��. '�1.� � ?�.)•. (project location) to{('>_ (Owner's address) �} }t yam,,,, r1 +z ,l�7 ( ) 1 ' ., .. u. ' .L�r:E•��L*e.. :'.'.�r'y ile'ec. 1/.lt L3_St _3rNYI�13j:ltC'•�, (.:� .PI `Y f t Owner's contactperson)title (project description) its r L�,y f . ( (title) -'44 c �;r r��>,1(r,•`f (project stai*ompletion dates) (contract value) (phone) (email) CAO S. 6. FORM 5 STATEMENT ()F EXP? RIENCE OF $IDDER ( ,ram (pro ect name) ! (project _� L" �Il �4`Y i•'YU%i Si i �-c7 i�.t�1r'r _� s�• - � ttYr^ �,'�a (project location) 1 T fVnI l (protect &scription)j u'v�) :Getw z5.n.( (Owner's contact person) (title) J .. 2_�'7.�.-."'j ``'°`t J£'t • >ri1 ( t (project completion date) (contract value) (phone) (eYhail) {project (project location),) ' �..� •i�r� (project (Owner's address) 1. ��f1j Cz'•P• 1 .".. t w>'i•ie. t7^S'tL`.-- (project description)_-f'(�rC.t i�.f,(Owner's contact person) f �'��ef-• ! s� C1�1 r1 ' (Phone) (erilan) (project comp date) (contract value) {project name project location) u (project description) ">�a4r �c':�'�Y;'1' ;=Yr{��' (project completion date ~� (contract value) Company: Signature: (Ow(n"e�r's adjdress) �/y,I I ev 4 (Owwner's contact person) (title) 1 -�;�'�-•'�lr.�...C✓''`�i.�"� f.kf]t1 t;�.l:,{"t'Y'1""�;�ilr�"� ."tT r ��•sE°1"i��'r..�'�'1�j, (phone} (email) J CAO G = TRENGH SA FETX AGT.` , , Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of Florida) eff.'ective October 1, 1990. The Bidder further identifies the cost to be summarized below: Trench Safety Measure tD.escription} Units of Measure •LF SY Unit C uanti Unit Cost TOTAL � � ; � � Fail�u-e to complete the above may itsult i.n the Bid being declared. non�respansive. Company: !': i� {��i��,'�� ,.� �" Signature; Y__,' Extended Cost Date: f � �� I PT— eA O FORM 7.- BID BOND KNOW ALL MEN BY THESE PRESENTS, that we Infinite Constructi_ai. LLC _ (herein after called the Principal) and The Ohio CasualtjInsuiance Company _ (herein called the Surety), a corporation chartered and existing under the laws of the State of �,g with its principal offices in the city of Boston, MA and authorized to do business in the State of Florida _ are held and firmly bound unto the Cb1ti.ej1 C•. wy Bard of C:o_uaW.0 tmnissioners_ (hereinafter called the Owner); in the full and just sum of good and lawful money of the United States of America, to be paid upon demand of the Owner, to which payment well and truly to be made, the Principal and the Surety bind themselves, their heirs, and executors, administrators, and assigns, jointly and severally and firmly by these presents. Whereas, the Principal is about to submit, or has submitted to the Owner, a Bid for furnishing air labor, materials, equipment and incidentals necessary to furnish, install, and fully complete the Mork on the Project known as Bid No. 19-7630 Barefoot Beach North Access Boardwalk and Pavilion Replacement. d Agreement 1vOW, THEREFORE, if the Owner shall accept the Bid of the PRINCIPAL and the .PRINCIPAL, shall enter into the require with the Owner and within ten days after the date of a written Notice of Award in accordance with the terms of such Bid, and give such bond or bonds in an amount of 100% the total Contract Amount as specified in the Bidding Documents or Contract Documents with good and sufficient surely for the faithful performance of the Agreement and for the prompt payment of labor, materials and supplies furnished in the prosecution thereof or, in the event of the failure of the PRINCIPAL to enter into such Agreement or to give such bond or bonds, and deliver to Owner the required certificates of insurance, if the PRINCIPAL shall pay to the OBLIGEE•the fixed sum of noted above as liquidated damages, and not as a penalty, as provided in the Bidding Documents, then, lhisa),bligation shall be null and void, otherwise to remain in full force and effect. IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly signed and sealod t;iis l,t:_ , daxy :of August > 2019 BY Gowater Infinite Construction, LLC Principal <r' The Ohio Casual Insurance Com an Surety ,Seal) .. Appointed Producing Agent for The Ohio Casualty hlsurance Conapany Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement form attached to the Bidding Documents within ten (10) calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents. The bid security attached is to become the property of the Owner in the event the Agreement, insurance Certificates and Bonds are not executed and delivered to Owner within the time above set forth, as liquidated damages, for the delay and additional expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period. In the event of such failure, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. !t is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it fails to execute and deliver the Agreement, Insurance Certificates, and Bonds as required hereunder. The Successful Bidder hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely manner. Upon receipt of the signed and approved agreement and Purchase Order, the undersigned proposes to commence work at the site within five (S) calendar days from the commencement date stipulated in the written Notice to Proceed unless the Project Manager, in writing, subsequently notifies the Contractor of a modified (later) commencement date. The undersigned further agrees to substantially complete all work covered by this Bid within ninety. (90) consecutive calendar days, computed by excluding the commencement date and including the last day of such period, and to be fully completed to the point of final acceptance by the Owner within Thirty (30) consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. P,cspectfully Submitted: State of FL - County of 1-4eet AO:gj «�) i. r 1'nc, , ,1{n�n 1� C'�, (.f �x �,13r" being first duly sworn on oath deposes and says that the Bidder on the above Bid is organized as indicated and that all statements herein made are made on behalf of such Bidder and that this deponent is authorized to make them. •��F�,11. also deposes and says that it has examined and carefully prepared its Bid from the Bidding Documents, including the Contract Drawings and Specifications and has checked the same in detail before submitting this Bid; that the statements contained herein are true and correct. (a) Corporation The Bidder is a corporation organized and existing under the laws of the State of ). which operates under the legal name of _�_;.,',tQ t':Y,,- �� %'�� 1 C and the full names of its officers are as follows: Secretary Treasurer Mana Thger e r, ;Marra � _ is authorized to sign construction bids and contracts for the company hy--action- Rts- Beard-ofDirectors-takenvvhtes-hc eto attaehed (strike out this last sentence if not applicable). (b) Co -Partnership The Bidder is a co -partnership consisting of individual partners whose full names are as follows: The co -partnership does business under the legal name of: (c) Individual The Bidder is an individual whose full name is _�, and if operating under a trade name, said trade name is Complete for information contained in (a) Corporation, (b) Co -Partnership or (c) Individual from previous page. Legal Enti BY: tl i tt' 11 'ryy'ri� Name of Bidder d s Signature ell Title STATE OF l�� COIINTI' OF 1~�� The foregoing instrument was acknowledged before me this day of r 201 by as , n^ of(nn: , 4 ,mo 1-Ie she is personall�knowt7;'to rile or has produced corporation, on behalf of the corporation. as identificatioiiaid id not) take an oath. ra My Commission Expires: ficd i(-f$9-. i (Sighture of Notary) NAME: �ptH4i1t11/�� (egibly Printed) �`�t�t ,� (AFF`� � $�b t �✓i NotaryPublic, State of F t • MGG490t79 v O' • ;°' 8°wed �� °°�• �� U ,kalary OF�,`�� rr;I Z/C, STAI `�\�v�x� Cq 0 THiS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND - This Power of Attorney limits the acts of those named herein, and they have no authority to bind the company except in the manner and to the extent herein stated. Certificate P,o. 7990484 Lfberfy Mutual Insurance Company The Ohio Casualty Insurance Company West American insurance Company KNOthdN ALL PERSONS 3Y Thl[ iE PRESEtdTS: That i'he C)hio Casualty Insurance Company is a rnrporaiion duty orya lead under the taws at the State of Navi Hampshire, that Liherty Nelulual Insurance Company is a corporation duly organized under the laws of the Stale of Massachusetts. and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the 'Companies`), pursuant to and by aut(tarfty herein sat fort;, (tees heraby name, constitute and appoint, Glenn Arvanitis; Teresa LL.Durhatn; Lisa Roseland; Cheryl Fqf�• Kim E. Niv; Susan L. Reich; Jeffre Reich; Gloria A. Rfchards ail of the city of Maitland , state of FL ___-____ each individually ff there be more than one named, its Prue and lawful atiomay-indent to make, execute, sea!, aaknowiedge alid deliver, for and on its behalf as surely and as its aot and deed; any ,and all undertakings, bonds, recognizanoes and oilec-r surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and aliested by the secretary of the Companies in iheir oven proper persons. Itv 4VIT?�fE$S WHFR'c.UF, this Pov.er cf Attorney has been subsrxfbed by an authorized officer or official of the.Caml;amies.and Ilse corporate. seals of the Ccmfianfes have been aff!zed. €hereto this 25111 day of January 2018 _ d° s �i tad' \\ 1 E s"rATE OF PEtdNSYLkill NIA ss CiDUNTI' OF f:40NTG0istERY The Ohio Casualty Insurance Coinpaity Liberty Mutual Insurance Company West American Insurance Company i F, ter (David M, Carey,'A>sisianl Srnrretary On this 251h day of January„, ,, 2018 , before ina personally appeared David Ivy, Carey: who acknowledycd himself to he lire Assistant Secretary of Liberty leluivai insurance Company, The Ohio Casualty Company, and vv'esl American Insurance Company, and that ha, as such, being authorized so to do, execute the foregoing instrument far the purposes ID W therein contained by signing on behall of the corporations by himself as a duly authorized officer, IN WI CNESS WHEREOF, i have hereunto subscribed try name and affixed my itotarfai Baal at King of Prussia, Pennsylvania, an the day and year first above iyrilten. �p ° � Cflh1t10hFYEltt TH OF PC1iH5YLVhtQiA If \ J, ti c ri st'� l t 1 IuL I L-f t. Y� —_... _—_ _ .. _ ..._—__.........__.__-_ j unr: r is nonr r t nt, r T, (o, rely Teresa Pasteila, Notary Public rtr.�c �l_,.r 5tt.t(,2d I? ^�S 5 V:�!' ,.Y This Power of Aitamey is made and executed pursuant to and by authority of the following Sylavrs and Authorizations of The Ohio Casueity insurance Company, Liberty Mutual Insurance Co.rpany, and irvesi.Amarica;i insurance Conkparly r.hicn rasahitfons are new in fu;{ for(= and effect rHading as fo!loi;s; ARTICLE iV- OFFICERS - Section 12. Power of Attorney. Any oflicer or other official of the Corporation authorized for that purpose. in ivrifing by the Chairman or the President, and subject to such liroifation as the Chairman or the President may prescribe, shall appoint such atlomeys•in-fact. as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and de'iv�vr as surely any and ail underiakings, bonds, recognizances and other surety obligations. Such attomcys-in•fact, subiect to tiro imittitions set forth in their respective powers of aitomev, shall have full power to bind the Corporation by their signature and exe ulion of any such inslitiments and to attach thereto the seat of the Corporation, Wien so executed, such instruments shall be as binding as it signed by the President and attested to by tat: Secretary. Any pourer or authority granted to any representative or attorneyin-fact under III provisions of this article may be revoked at any time by the Board. the Chairman, the President trip by the officer or officers ;ranting such power or authority. ARTICLE Xlil - Execution of Contracts - SECTION 5. Surely Bonds and Undertakings. Any officer of the Company authorized for that ptrrpose in writing by the chairman or the president, arld subject to such limilations es the chairman or the president may proscribe, shall appoint such ral!orneys-in-fact. as may be neca;ssary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings. bends, rc coon>_ances and other surely obligations. such attorneys-ih-fact subject to the fmitahons set forth in their respective pouters of aitarney, shaft have full pav ar to bind the Company by !heir signature and execution of any such instruments and to a!tach thereto the seal of the Company. 'Nlasn so executed such instruments shall he as.binding as if signed by the president and attested by.the secretary. Certiiacata of pesiynation -1"he President of fine Company, acting pursuant io (ne Bylav:s cf the Company, authorxes Oavid P9. Carey, Assistant 8ecreiary to appoint such allortieys*in- fact as may be necessary to act on behalf of the Company to nrake, execute, seal, acknoiviedge and defiv°e as surety any and all undertakings; bonds: roc nizancas and other surety obiigaiiens. Authorization - By unanimous consent of the Company's Board of Directors, the Company consents that incsimile or rnuachorkic<diy reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. 1. Renee C. Llowelyn, the undersigned. Assistant Serrelary, The Ohio Casualty Insurance Company, Liberty Mutual insurance Company, and blest American Insurance Company do hereby certify that the original potter of attorney of vdlich the foregoing is a full, true and correct copy of the Poiver of Altomey executed by said Companies, is fit full force and effect and kis not b=Hn wiloked. IN TESTIMONY WHEREOF. I have hereunto set my hand and affixed like seals of said Companies this day of 1Y r r C t 20_� IY;1 't Ra;ieH C. Sarretary 29of10Q Cozier County Administrative Services Deparbnent pin cireement 8entices dhi ,icr FORM 9 - Co:Irt.rc� o> ThTz Ri sr. ArrmnvtT The Vendor certifies that, to the best of its knowledge and belief, the past and current work on. any Collier County project affiliated with this solicitation does not pose an organizational conflict as described by one of the three categories below: Biased ground rules — The firm has not set the "ground rules" for affiliated past or current Collier County project identified above (e.g., writing a procurement's statement of work, specifications, or performing systems engineering and technical direction for the procurement) which appears to skew the competition in favor of my firm. Impaired objectivity — The firm has not performed work on an affiliated past or current Collier County project .identified above to evaluate proposals / past performance of itself or a competitor, which calls into question the contractor's ability to render impartial advice to the government. Unequal access to information —The firm has not had access to nonpublic information as part of its performance of a Collier County project identified above which may have provided the contractor (or an affiliate) with an unfair competitive advantage in current or future solicitations and contracts. hi addition to this signed affidavit, the contractor /vendor must provide the following: 1. All documents produced as a result of the work completed in the past or currently being worked on for the above -mentioned project; and, 2, indicate if the information produced was obtained as a matter of public record (in the "sunshine") or through non-public (not in the "sunshine") conversation (s), meeting(s), document(s) and/or other means. Failure to disclose all material or having an organizational conflict in one or more of the three categories above be identified, may result in the disqualification for future solicitations affiliated with the above referenced project(s). By the signature below, the firm (employees, officers and/or agents) certifies, and hereby discloses, that, to the best of their knowledge and belief, all relevant facts concerning past; present, or currently planned interest or activity (financial:, contractual, organizational, or otherwise) which relates to the project identified above has been fully disclosed and does not pose an organizational conflict. Signature and Print Name: -- Title of Signatory:---- ��r�` [ie� �t��t.�.t� ..�,, Administrative �2tvices De}k�itment Procus��ient Sernces Divisiprs r+oiil.`i 1 U - `Vt?NDUR DJ:C`,LrlI2A'CitaN STA'I'G;11T�1`i 3' E3(�ARD CJF COUNTY COA9iv1ISS1D'NFRS Collier County Government Complex Naples, Flot•ida 34112 bear Canunissione�s: Tlae undersigned, as Vendor declares drat this response is made without connection or a�•rangament wfth any other person and this proposal is in every respect fair and made in goad faith, without collusiojr or fraud. The Vendor agrees, it this solicitation submittal is accepted, to execute a Collier County document for the purpose of establishing a Formal contractual relationship befiveen the firm and Collier County, for the performance of all requirements to which the solicitation pertains. The Vendor states that the submitted is based upon the dacuznents listed by the above re:Ferenced Solicitation..!+ uriher, the vendor agrees that if awarded a contract tar tfrese goods and/or services, the vendor wilt aot be eligible to compete, snbrnit a propose}, be a��•arded, or perform as asub-vendor for any future associated ii�it3r tivork that is a result «fthis awarded Contract. IhT W.[TNE;SS WII:E;RLOF, Wl� have hereunto subscribed our names an this ._�`aL day of___��,�{�•�_._ __, 20 }� in the Cauniy of ��>r' -- _.�...__,i�_�,_....._..._.—; m the State of_.__._�__I•��',��_r_._• `' F'irm's t..egal Name: Address: City, State, Zip Code: Florida. Certificate of Authority Document Number Federal Tax Iclentifcation Number *CCR # or GAGE Code *Only if Grant PYurded Telephone: Signature by: ("['yped and written) Title: .. •tom �fkr � 'fit' �-r�="vt•r�- t'°=•.� � t Z �:-�`ie.� l�E Ire., •' fir;' �`—',s. , .� nf# {i � to i i1 E� r_r Additional Contact Information Send payments to: (required if different from Company name used as payee above) Contact name:i;(.t. Title: Address: t4, L i C JcLle%lu,t f' Ciq=, State, ZIP Office servicing Collier County to place orders (required if different from above) Contact name: Title: �1.ddress: City, State, Zll' Telephone: E:;l: mai Secondary C;ontaet for this Solicitation: Emai L• I'ltone: Adntinistraii,re Services Departiment Procurement Szomce ();A IN4 FURM f1 - I�t�ttGtt�rtoiy Ari:��vtr C>;x�t•tr'cArto� this Affidavit is required and should be signed, notarized by an author ized principa ofthe tirm and submitted with forrnal solicitation submittals. Further, Vendors are required to enroll in the 1 -Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Vendor's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Failure to include this Affidavit and acceptable evidence of enrollment in the F-Verify program may deem the Vendor's proposal as non- responsive. Collier County will not intentionally award County conta•acts to any Vendor who l.no�vingly employs unautliori�led alien workers, constituting a violation of the eanployment provision contained in 8 U.S.C. Section 1324 a(e) Section 274A(e) of the hmmigration and Nationality Act ("INA"). Collier County may consider the employment by any Vendor of unauthorized aliens a violation of Section 274A (e) of the 1NA. Such Violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be grounds for unilateral termination of the contract by Collier County. Vendor attests that they are fiilly compliant with all applicable lnmigratian laws (specifically to the 1.986 littmigratioti Act antl subsequent Amendment(s)) and agrees to comply with the provisions of the Memorandum of Understanding with &Verity and to provide proof of enrollment irt'I'he Employment Eligibility Verification System. (E-Verify), operated by the Department ofl-lomeland Security in partnership with the Social Security Administration at the time of submission of the Vendor's proposal. Company Name hi'lltt Name Signature St�3te of �.1 County of 1_..r_�;' z ' • I tilt✓ f{ ,.. The signee ofthese Ai'fidavit guarantees, as evidenced by the sworn affidavit requited herein, the truth and accuracy of this affidavit to 6tterrogatories hereinafter made. Commission No.: l-�>t�`��i t 4`l`�( ,7lt .la £Il�•t�1;i ��?3 J DOA C014"ty Ackn"visirtnrz Servers bepmunet:` FIGWlv`� WIl! :i Y`11i.n5 6'RSCd', FORM 12 - v t.RDOR SuBSTI I U I E W —9 Kequest for Taxpaver Identification Number and Certification l.n accordance with the Internal Revenue Service regulations, Collier County is requited to collect the fallowing information for tax reporting; purposes from individuals and companies who do business with the County (including social security numbers if used by the individual or company for tax reporting purposes). Florida Statute 119.071(5) requires that the county notify you in writing of the reason for collecting this information, which will be used for no other purpose than herein stated, Please complete all information that applies to your business and return with your quote or proposal. 1. General Information (provide all information) (cgs Shown On income i{Iti retirr•n) Business Name (if different from to aver Warne) Address ��ar �; !rye City State •�)-',�r,rl�a ...._.�. Zq� j '',•�% Lir} r Email rY�'• I'7f . 'i , _^YY � i" f`.�'l ��!4'Y' i`j . �" ��ta•� Order Information (Must be filled out) Remit/ Payment Information (Must be filled out) Address d tjC{ 1�� P, r s �� l Address 6v'7t-I C{ li i Is � � �� A'J City s •� �-� 1>; °� State � )_ ,� Zip ,�_, I City .Y� .j State �R_____ I ip �—�=— u y mail�r�-� Email 2. Company Status (check only one) ole Proprietor _Tax Exempt (Federal income tax-exempt entity under tntet•nat Revenue Service guidelines tRC 501 (c) 3) �� Enter the tax classification (D =Disregarded lrrtit}-, C = t:o:•paraiian, P =- Pcn•tners/rip) 3. 'faxpaye.r Cdentification Number (for tcr.� re/�arlinf>�rtrpvscs• nn1Y) Federal. Tax Identification :Number (TIN) ___•_.—�?��'��_`-� t-�� — (Vendors who do not have a TIN, will be re uired to provide asocial security number prior to an award). 4. Sign and Date Forme, Certification: Under enatties o • per •m• 1, I certi , that the in orrnation slro�trn on this farrn is ct Signature r — -- Title to nr xraox�tca�e. Date —_f �16 Ii,,l I1 Phone Nunilier r r.Ac� IMPORTANT: Please read carefully, sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: v'1. "The Bid has been signed. The Bid prices offered have been reviewed. v The price extensions and totals have been checked. �$. Bid Schedule has been completed and attached. 15, Any required drawings, descriptive literature, etc, have been included. ,6. Any delivery information required is included. ,✓7. The following on-line standard documents have been reviewed in BidSync: V1. Construction bid instructions form Construction services agreement Purchase order terms and conditions S. All of the following bid forms have been completed and signed: V1. Bid Form (Form 1) Yf 0. Vendor Declaration Statement (Form 1.0) V2. Contractors Key Personnel (Form 2) 'fl . Immigration :Law Affidavit Certification. ./3. .Material Manufacturers (Form 3) (Form 11 A List of Major Subcontractors (Form.4) vl'2. Vendor Substitute W-9 (Form 12) v/. Statement of Experience (Form 5) 4/3. Bidders Checklist (Form 13 this form) ;,6. Trench Safety Act (Form 6) 14. Business tax Receipt (Collier County �7. Bid Bond Form (Form 7) Businesses Only) j$. Insurance and Bonding. Requirements (.Form 3) Vf6. Signed Grants Provisions Package (if A Conflict of Interest Affidavit (Form 9) applicable 9. Copies of required information have been attached Company's E-Verify profile page or memorandum of understanding \12. Certificate of Authority to Conduct Business in State of Florida 04 Any required professional licenses — valid and current (ie: General Contractors license, Underground Utility and Excavation, Builders, Trade Contractors, etc., as applicable, requested and/or required.) tilr0. If required, the amount of Bid bond has been checked, and the Bid bond or cashier's check has been. submitted. ,41. Any addenda have been signed and acknowledgement form. attached and included. X2. The Bid will be uploaded in time to be received no later than the specified opening date and time, otherwise the Bid cannot be considered. Bidder Name Sinature & T:itle llate Gompany ID Number: 789948 THE E-VERIFY MEMORANDUM OFUNDERSTAND[NG FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DHS) and the Infinite Construction LLC (Employer). The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E-Verify. E-Verify is a program that electronically confirms an employee's eligibility to work in the United States after completion of Form 1-9, Employment Eligibility Verification (Form I-9). This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer, the Social Security Administration (SSA), and DHS. Authority for the E-Verify program is found in Title IV, Subtitle A, of the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Pub. L. 104-208, 110 Stat. 3009, as amended (8 U.S.C. § 1324a note). The Federal Acquisition Regulation (FAR) Subpart 22,18, "Employment Eligibility Verification" and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal contractor) to use &Verify to verify the employment eligibility of certain employees working on Federal contracts. ARTICLE [[ RESPON0101LITIES A. RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system: a. Notice of E-Verify Participation b, Notice of Right to Work 2. The Employer agrees to provide to the SSA and DHS the names, titles, addresses, and telephone numbers of the Employer representatives to be contacted about E-Verify. The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes. 3. The Employer agrees to grant E-Verify access only to current employees who need E-Verify access. Employers must promptly terminate an employee's E-Verify access if the employer is separated from the company or no longer needs access to E-Verify. Page 1 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 1. £xC,lr VYP MA T•� Company ID Number: 789948 4. The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual. 5. The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases. a. The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by &Verify in order to continue using E-Verify. Failure to complete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify. 6. The Employer agrees to comply with current Form I-9 procedures, with two exceptions: aI If an employee presents a "List B" identity document, the Employer agrees to only accept "List B" documents that contain a photo. (List B documents identified in 8 C.F.R. § 274a.2(b)(1)(B)) can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218. b. If an employee presents a DHS Form 1-551 (Permanent Resident Card), Form I-766 (Employment Authorization Document), or U.S. Passport or Passport Card to complete Form I-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employee's Form I-9. The Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest. DHS may in the future designate other documents that activate the photo screening tool. Note: Subject only to the exceptions noted previously in this paragraph, employees still retain the right to present any List A, or List B and List C, document(s) to complete the Form I-9. 7. The Employer agrees to record the case verification number on the employee's Form I-9 or to print the screen containing the case verification number and attach it to the employee's Form I-9. 8, The Employer agrees that, although it participates in E-Verify, the Employer has a responsibility to complete, retain, and make available for inspection Forms I-9 that relate to its employees, or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 274B of the INA with respect to Form I-9 procedures. a. The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti -discrimination provision of the fNA: {1) List B identity documents must have photos, as described in paragraph 6 above; (2) When an Employer confirms the identity and employment eligibility of newly hired employee using &Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(a)(1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and $1,100 for each failure to notify DNS of continued employment following a final nonconfirmation; (4) If the Employer continues to employ an employee after receiving a final nonconfirmation, then the Employer is subject to a rebuttable presumption that it has knowingly Page 2 of 17 E-Verify MnU for Employers I Revision Date 06101l13 1 t ":,11110 Company ID Number; 789948 employed an unauthorized alien in violation of section 274A(a)(1)(A); and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b. DHS reserves the right to conduct Form k9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verify. 9. The Employer is strictly prohibited from creating an E-Verify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Forrn k9 was completed. The Employer agrees to create an E-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections 1 and 2 of Form I-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual. If E-Verify is temporarily unavailable, the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting, in good faith, to make inquiries during the period of unavailability. 10. The Employer agrees not to use E-Verify for pre -employment screening of job applicants, in support of any unlawful employment practice, or for any other use that this MOU or the E-Verify User Manual does not authorize. 11, The Employer must use E-Verify fior all new employees. The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU. Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article II.B of this MOU. 12. The Employer agrees to follow appropriate procedures (see Article III below) regarding tentative nonconfirmations. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees, The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmation based upon a photo mismatch, the Employer must take additional steps (see Article III.B. below) to contact DHS with information necessary to resolve the challenge. 13. The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA ar DMS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a.1(1)) that the employee is not work authorized. The Employer understands that an initial inability of the SSA or DHS automated verification system to verify work authorization, a tentative nonconfirmation, a case in continuance (indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized. In any of such cases, the employee must be provided a full and fair opportunity to contest the finding, and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status Page 3 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 Company ID Number: 789948 (including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding. pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued. If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment. Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218 (customer service) or 1-888-897-7781 (worker hotline). 14. The Employer agrees to comply with Title Vll of the Civil Rights Act of 1964 and section 274E of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of &Verify except as provided in part D below, or discharging or refusing to hire employees because they appear or sound 'foreign" or have received tentative nonconfirmations. The Employer further understands that any violation of the immigration -related unfair employment practices provisions in section 274B of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject the Employer to back pay awards, compensatory and punitive damages. Violations of either section 274B of the INA or Title VI may also lead to the termination of its participation in &Verify, If the Employer has any questions relating to the anti -discrimination provision, it should contact OSC at 1-800-255-8155 or 1-800-237-2515 (TDD). 15. The Employer agrees that it will use the information it receives from E-Verify only to confirm the employment eligibility of employees as authorized by this MOU. The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU, except for such dissemination as may be authorized in advance by SSA or DHS for legitimate purposes. 16. The Employer agrees to notify DHS immediately in the event of a breach of personal information. Breaches are defined as loss of control or unauthorized access to E-Verify persona{ data. All suspected or confirmed breaches should be reported by calling 1-888-464-4218 or via email at ::.Verify( dhs.gov. Please use "Privacy Incident — Password" in the subject line of your email when sending a breach report to E-Verify. 17. The Employer acknowledges that the information it receives from SSA is governed by the Privacy Act {5 U.S.C. § 552a(i)(1) and (3)) and the Social Security Act (42 U.S.C. 1306(a}). Any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties. 18. The Employer agrees to cooperate with DHS and SSA in their compliance monitoring and evaluation of E-Verify, which includes permitting DHS, SSA, their contractors and other agents, upon Page 4 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 C'fiO Company lD Number: 789948 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employers use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19. The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media. The Employer shall not describe its services as federally -approved, federally -certified, or federally -recognized, or use language with a similar intent on its website or other materials provided to the public. Entering Into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effect is false. 20. The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS, 21. The Employer agrees that E-Verify trademarks and logos may be used only under license by DHS/USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employers services; products, websites, or publications are sponsored by, endorsed by, licensed by, or affiliated with DHS, USCIS, or &Verify. 22. The Employer understands that if it uses E-Verify procedures for any purpose other than as authorized by this MOU, the Employer may be subject to appropriate legal action and termination of its participation in E-Verify according to this MOU. B. RESPQNSIBILITIES OF FEDERAL CONTRACTORS 1. If the Employer is a Federal contractor with the FAR E-Verify clause subject to the employment verification terms in Subpart 22.18 of the FAR, it will become familiar with and comply with the most current version of the E-Verify User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors. 2. In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must verify the employment eligibility of any Uemployee assigned to the contract" (as defined in FAR 22,1801). Once an employee has been verified through &Verify by the Employer, the Employer may not create a second case for the employee through E-Verify. a. An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verify employment eligibility of new hires using &Verify. The Employer must verify those employees who are working in the United States, whether or not they are assigned to the contract. Once the Employer begins verifying new hires, such verification of new hires must be initiated within three business days after the hire date. Once enrolled in E-Verify as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later, Page 5 of 17 E-Verify MOU for Employers l Revision Date 06/01/13 Company IC? Number: 789948 b. Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire. If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award, the Employer must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract. Such verification of new hires must be initiated within three business days after the date of hire. An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later. c. Federal contractors that are institu#ions of higher education (as defined at 20 U.S.C. 1001(a}), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract. Such Federal contractors may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986. Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later. d. Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United States who were hired after November 6, 1986, instead of verifying only those employees assigned to a covered Federal contract. After enrollment, Employers must elect to verify existing staff following DHS procedures and begin ::.Verify verification of all existing employees within 180 days after the election. e. The Employer may use a previously completed Form 1-9 as the basis for creating an E-Verify case for an employee assigned to a contract.as long as: That Form I-9 is complete (including the SSN) and complies with Article II.A.6, The employee's work authorization has not expired, and iii, The Employer has reviewed the Form I-9 information either in person or in communications with the employee #o ensure that the employee's Section 1, Form I-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U.S. citizen). f. The Employer shall complete a new Form I-9 consistent with Article Il.A.6 or update the previous Form I-9 to provide the necessary information if: The Employer cannot determine that Form I-9 complies with Article II.A.6, The employee's basis for work authorization as attested in Section 1 has expired or changed, or iii. The Form I-9 contains no SSN or is otherwise incomplete. Note: If Section 1 of Form I-9 is otherwise valid and up-to-date and the form otherwise complies with Page 6 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 ��Z. Fiy Ii1III <`' Company ID Number; 789948 Article II.C.5, but reflects documentation (such as a U.S. passport or Form I-551) that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article 11.A.5, subject to any additional or superseding instructions that may be provided on this subject in the &Verify User Manual. g. The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3. The Employer understands that if it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements. C. RESPONSIBILITIES OF SSA 1. SSA agrees to allow DHS to compare data provided by the Employer against SSA's database. SSA sends DHS confirmation that the data sent either matches or does not match the information in SSA's database. 2. SSA agrees to safeguard the information the Employer provides through E-Verify procedures. SSA also agrees to limit access to such information, as is appropriate by law, to individuals responsible for the verification of Social Security numbers or responsible for evaluation of &Verify or such other persons or entities who may be authorized by SSA as governed by the Privacy Act (5 U.S.C. § 552a), the Social Security Act (42 U.S.C. 1806(a)), and SSA regulations (20 CFR Part401). 3. SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry. E-Verify provides the information to the Employer. 4. SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence. If the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, if appropriate, within the eight -day period unless SSA determines that more than eight days may be necessary. In such cases, SSA will provide additional instructions to the employee. If the employee does not visit SSA in the time allowed, E-Verify may provide a final nonconfirmation to the employer. Note: If an Employer experiences technical problems, or has a policy question, the employer should contact E-Verify at 1-888-464-4218. D. RESPONSIBILITIES OF DHS 1. DHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct, to the extent authorized by this MQU: a. Automated verification checks on alien employees by electronic means, and Page 7 of 17 &Verify MDu for Employers I Revision Date 06/01/13 } Company ID Number: 789948 b. Photo verification checks (when available) on employees. 2. DHS agrees to assist the Employer with operational problems associated with the Employer's participation in &Verify. DHS agrees to provide the Employer names, titles, .addresses, and telephone numbers of DHS representatives to be contacted during the E-Verify process. 3. DHS agrees to provide to the Employer with access to E-Verify training materials as well as an -Verify User Manual that contain instructions on E-Verify policies, procedures, and requirements for both SSA and DHS, including restrictions on the use of &Verify. 4. DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the &Verify User Manual. Even without changes to E-Verify; DHS reserves the right to require employers to take mandatory refresher tutorials. 5. DWS agrees to provide to the Employer a notice, which indicates the Employer's participation in E-Verify. DHS also agrees to provide to the Employer antidiscrimination notices issued by the Office of Special Counsel for Immigration -Related Unfair Employment Practices (OSC), Civil Rights Division, U.S. Department of Justice. 6. DHS agrees to issue each of the Employer's E-Verify users a unique user identification number and password that permits them to log in to E-Verify. 7. DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation Of E-Venly, or to such other persons or entities as may be authorized by applicable law. Information will be used only to verify the accuracy of Social Security numbers and employment eligibility, to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements. 8. DHS agrees to provide a means of automated verification that provides (in conjunction with SSA verification procedures) confirmation or tentative nonconfirmation of employees' employment eligibility within three Federal Government work days of the initial inquiry. 9. DHS agrees to provide a means of secondary verification (including updating DHS records) for employees who contest DHS tentative nonconfirmations and photo mismatch tentative nonconfirmations, This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to DHS, unless DHS determines that more than 10 days may be necessary. In such cases, DHS will provide additional verification instructions. ARTICLE Ill REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA 1. If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's &Verify Page 8 of 17 E-Verify mou for Employers I Revision Date 06/01/13 Company lD Number: 789948 case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she wi(I contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. After a tentative nonconfirmation, the Employer wiA refer employees to SSA field offices only as directed by E-Verify. The Employer must record the case verification number, review the employee information submitted to E-Verify to identify any errors, and find out whether the employee contests the tentative nonconfirmation. The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again if this review indicates a need to do so. 4. The Employer will instruct the employee to visit an SSA office within eight Federal Government work days. SSA will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 5. While waiting for case results, the Employer agrees to check the E-Verify system regularly for case updates. 6. The Employer agrees not to ask the employee to obtain a printout from the Social Security Administration number database (the Numident) or other written verification of the SSN from the SSA. Ei. REFERRAL TO DHS 1. If the Employer receives a tentative nonconfirmation issued by DHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's &Verify case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the ives tentative nonconfirmation as soon as possible after the Employer recethe tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. The Employer agrees to refer individuals to DHS only when the employee chooses to contest a tentative nonconfirmation. 4. If the employee contests a tentative nonconfirmation issued by DHS, the Employer will instruct the Page 9 of 17 &Verify MOU for Employers I Revision Date 06/01/13 Company ED Number: , 9948 employee to contact DHS through its toll -free hotline (as found on the referral letter) within eight Federal Government work days. 56 if the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph 1 of this section for tentative nonconfirmations, generally. 6. The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1-551, Form I-766, U.S. Passport, or passport card to DHS for review by: a. Scanning and uploading the document, or b. Sending a photocopy of the document by express mail (furnished and paid for by the employer). 7. The Employer understands that if it cannot determine whether there is a photo match/mismatch, the Employer must forward the employee's documentation to DHS as described in the preceding paragraph. The Employer agrees to resolve the case as specified by the DHS representative who will determine the photo match or mismatch. 8. DHS will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 9. While waiting for case results, the Employer agrees to check the &Verify system regularly for case updates. ARTICLE IV SERVICE pROViSIONS A. NO SERVICE FEES 1. SSA and DHS will not charge the Employer for verification services perfiormed under this MQU. The Employer is responsible for providing equipment needed to make inquiries. To access &Verify, an Employer will need a personal computer with Internet access. ARTICLE V MODIFICATION AND TERMINATION A. MODIFICATION 1. This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and DHS operates the E-Verify program unless modified in writing by the mutual consent of all parties, 2. Any and all E-Verify system enhancements by DHS or SSA, including but not.limited to E-Verify checking against additional data sources and instituting new verification policies or procedures, will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes. Page 10 of W E-Verify mou for Employers I Revision Date 06/01/13 Y �{ Company ID Number: 789948 B. TERMINATION 1. The Employer may terminate this MOU and its participation in E-Verify at any time upon 30 days prior written notice to the other parties. 2. Notwithstanding Article V, part A of this MOU, DHS may terminate this MOU, and thereby the Employer's participation in &Verify, with or without notice at any time if deemed necessary because of the requirements of law or policy, or upon a determination by SSA or DHS that there has been a breach of system integrity or security by the Employer, or a failure on the part of the Employer to comply with established &Verify procedures and/or legal requirements. The Employer understands that if it is a Federal contractor, termination of this MOU by any party for any reason may negatively affect the performance of its contractual responsibilities. Similarly, the Employer understands that if it is in a state where &Verify is mandatory, termination of this by any party MOU may negatively affect the Employer's business. 3. An Employer that is a Federal contractor may terminate this MOU when the Federal contract that requires its participation in E-Verify is terminated or completed. In such cases, the Federal contractor must provide written notice to DHS. If an Employer that is a Federal contractor fails to provide such notice, then that Employer will remain an &Verify participant, will remain bound by the terms of this MOU that apply to non -Federal contractor participants, and will be required to use the &Verify procedures to verify the employment eligibility of all newly hired employees. 4. The Employer agrees that E-Verify is not liable for any losses, financial or otherwise, if the Employer is terminated from E4erify. ARTICLE VI PARTIES A. Some or all SSA and DHS responsibilities under this MOU may be performed by contractor(s), and SSA and DHS may adjust verification responsibilities between each other as necessary. By separate agreement with DHS, SSA has agreed to perform its responsibilities as described in this MOU. B. Nothing in this MOU is intended, or should be construed, to create any right or benefit, substantive or procedural, enforceable at law by any third party against the United States, its agencies, officers, or employees, or against the Employer, its agents, officers, or employees. C. The Employer may not assign, directly or indirectly, whether by operation of law, change of control or merger, all or any part of its rights or obligations under this MOU without the prior written consent of DHS, which consent shall not be unreasonably withheld or delayed. Any attempt to sublicense, assign, or transfer any of the rights, duties, or obligations herein is void. D. Each party shall be solely responsible for defending any claim or action against it arising out of or related to E-Verify or this MOU, whether civil or criminal, and for any liability wherefrom, including (but not limited to) any dispute between the Employer and any other person or entity regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by the Employer. E. The Employer understands that its participation in E-Verify is not confidential information and may be disclosed as authorized or required by law and DHS or SSA policy, including but not limited to, Page 11 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 Company ID Number: 789948 Congressional oversight, E-Verify publicity and media inquiries, determinations of compliance with Federal contractual requirements, and responses to inquiries under the Freedom of Information Act (FaIA). F. The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer and DHS respectively. The Employer understands that any inaccurate statement, representation, data or other information provided to DHS may subject the Employer, its subcontractors, its employees, or its representatives to: (1) prosecution for false statements pursuant to 18 U.S.C. 1001 and/or; (2) immediate termination of its MOU and/or; (3) possible debarment or suspension. 1 The foregoing constitutes the full agreement on this subject between DHS and the Employer. To be accepted as an E-Verify participant, you should only sign the Employer's Section of the signature page. If you have any questions, contact E=Verify at 1-8884644218. Page 12 of 17 E-Verify MOU for Employers � Revision Date 06/01t13 Company ID Number: f VVC7 Approved by: Em ployer Infinite Construction LLC Name (Please Type or Print) �4Title Paulius Kirilinas ;Signature Date Electronically signed 06/12/2014 Department of Homeland Security —Verification Division _ Name (Please Type or Print) Title USCIS Verification Division Signature 'Date Electronically Signed 06/13/2014 Page 13 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 Company ID Number: 789948 Information Required for the E4erify Program Information relating to your Company: Infinite Construction LLC Company Name � i � r 6749 Idlewild St, Fort Myers, FL 39966 Company Facility Address Company Alternate Address i FCou:nt:yor Parish LEE iEmployer Identification Number 464726900 North American Industry 236 Classification Systems Code 'Parent Company i I Number of Employees j 1 to 4 Number of Sites Verified for 3 Page 14 of 17 E-Verify MOu for Employers I Revision Date 06101/13 Company w Number, 789948 Are you verifying for more than 1 each State: FLORIDA. 3 site(s) s- site? If yes, please provide the number of sites verified for In Page 15 of 17 E-Verify N10U for Employers � Revision Date 06/01113 K { �.jyn lltlil° Company ID Number: 789948 Information relating to the Program Administrators) for your Company on policy questions or operational problems: Name Vilija Kirilinas Phone Number (239) 826 - 6521 Fax Number Email Address pkirilinas@infioonst.com Name Paulius Kirilinas Phone Number (239) 826 - 1268 Fax Number (941) 234 - 9123 Email Address pkirilinas@inficonst.com Page 16 of 17 E-Verify MOU for Employers � Revision Date 06/01/13 Company ID Number: 789948 Page intentionally left blank Page 17 of 17 E-Verify MOU for Employers � Revision Date 06/01J13 7W /2019 Detail by Entity Name u ;igy 4 Tej % �F �i s ! C ivlsinn of C�rporutia is / Seai�cii Recarcis / r)einii By Docurrent. Nu�l i� r / earl �� Mama Florida Limited Liability Company INFINITE CONSTRUCTION, LLC Filing Informatio Document Number FEI/EIN Number Date Filed Effective Date State Status Principal Address 6749 IDLEWILD ST. FORT MYERS, FL 33966 Mailing Address 6749 IDLEWILD ST. FORT MYERS, FL 33966 L14000D25539 434726900 02/ 13/2014 02/13/2014 FL ACTIVE Registered Agent Name & Ad_dress KIRILINAS, VILIJA 6749 IDLEWILD ST. FORT MYERS, FL 33966 Name Changed: 01/28/2019 Authorized Perscrn(s) pefaii Name &Address Title AMBR KIRILINAS, PAULIUS 6749 IDLEWILD ST. FORT MYERS, FL 33966 Title AMBR KIRILINAS, VILIJA 6749 IDLEWILD ST. FORT MYERS, FL 33966 Annual Repor s search.sunbiz.org/Inquiry/CorporationSearch/SearchResuitDetaii?inquirytype=EntityName&directiohType=lnitiai&searchNameOrder=lNF[NITECON 7/31/2019 Report Year Filed Date 2017 01 /09/2017 2018 01/05/2018 2019 01128/2019 Document Images Ott28,2019 •-ANNU_P_� REPC)R'f C11tU51Lt�1H_ _}iNtvliFll IjEP�)i2T (J i�JS1101 f_• _Ht�NUlai_t�EPL)RT U3/90i20'18 -- ANNt_;AL R[PS3R7 (i,1`�CIilQ1.5 -• ANNt;r�,L. RE"Ut_ZT O)./?.;,';?C)tA_. �l_i. �(�8 {; I_ltjt�_C i.;E'.I)ilk,j Detail by Entity Name \%ie;v nnage in POf Prrmat \riev�• hjzage In NL`f= iorn�at V'se�v rmagrs (ri PUF forma View nnaga in r3L',F format \ticw image in Pt;F farma3 Viev,� i�na,e in f'DF (orm�i ��lt Q search.sunbiz,org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directlonType=1 nitial&searchNameOrder=l NFINITECONST, .. 2/2 I i i ? A•� ! � t� ' `t�7 i ; C� '-'-- E z O � � h Q � o W = w -v W � � � � W �' � � GG Q w w °' N s J Q p h � u Q � � _ r; � r � � a Z � � � ' o � c t1 i N : N � v � 's= tC Lid s OG --' ` r J' �+-� u o i i .{.� G � t J •� o 3 � V J �. W � ,� { f O � � Cn x � `= o � �. Z � l� d � z il? � W � � � v > ® �„ �- '� o � U � o o � � i a :.� ', u W ~ ` � � j i +t ,tArtrl� �` ,�' � I� jai , �'� a 3� • ,� �{tj is v � � •� �+i� dr �' �- j U EXHIBIT A-3: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Paulius Kirilinas Miguel Flores Personnel Category Construction Superintendent Project Manager 10 Construction Services Agreement: Revised 072118 INSTR 5771199 OR 5678 PG 1707 RECORDED 9/27/2019 1:13 PM PAGES 7 CLERK OF THE CIRCUIT COURT AND COMPTROLLER, COLLIER COUNTY FLORIDA REC $61.00 EXHIBIT B-1:PUBLIC PAYMENT BONb 194630 Bond No. 41K000110, executed in 2 counterparts Contract No. 19-7630 KNOW ALL MEN BY THESE PRESENTS: That Infinite Construction LLC, 6749 _ Idlewild St Ft Myers FL 33966 (239) 823-6929 as Principal, and The Ohio Casually Insurance Company as Surety, located at 175 Berkeley Street Boston MA 02116 (617) M7-M500 (Business Address) are held and firmly bound to The Board of County Commissioners of as Obligee in the SUM of Two Hundred Twenty -Five Thousand Three Hundred Forty -Three and 28/100--($225,343.28------- ) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the 27th day of August 2019 with Obligee for Contract No. 194630 Barefoot Beach North Access** in ----------- -------------- ------------ accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as denned in secnon eoo.u;�ti}, rionua �td�u��s, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void, otherwise it remains in full force, Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be flied by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this 26th day of September 2019 , the name of each party being affixed and these presents duly signed by its under -signed representative, pursuant to authority of its governing body. *Collier County, Florida, 15000 Livingston Road, Naples, FL 34109 (239) 2524020 **Boardwalk and Pavilion Replacement, 5901 Bonita Beach Rd., Bonita Springs, FL 34134 11 Conslructlon Services Agreement; Revised 072118 O Cq U OR 5678 PG 1708 Signed, sealed and delivered in the presence of: Witnesse as to Principal AW1 Flaer, STATE OF �t_•,r•tt(b COUNTY OF r. PRINCIPAL : t�:1� Infinite Construction, LLC00 BY: NAME$ Pnuh'uz� 1 iC ALI.S ITS: t) ,1 r The foregoing instrument was acknowledged before me this �7�t. day of 59� .�,�- 20.L�.. by r as mlec- of a FL corporation, on behalf of the corporatio a she is ersona ly known o me OR has produced as identification an did did not) take a . My Corry koa ��/ MCI ICE, g1 (Signature 6f Notary) _ �cc3nsotrs ATTEST: Witnesses to Surety NAME: * _ ( OW�ibly Printed) Notary Public, State of . FI ,.'; Commission No.: Cf OQol�Q SURETY: The Ohio Casualty Insurance Company (Printed Name) (Business Address (Authorized Signature) (Printed Name) 12 Construction Services Agreement' Revised 072118 C7:apY:�E:3 PG 1709 (�r Lk N Teresa L, Durham Witnesses Anita Navarra STATE OF Florida The Ohio rq Casualty Insurance Coiniail •r�`y y Y, ✓mlot oil as As Attorney in Fact (Attach Power of Attorney) �"'•.� phut) Lisa Roseland, Attornev-In-Fact & FL (Printed Name) Licensed Resident Agent* 175 Berkeley Street .t , Boston MA 02116 (Business Address) 61( 7)357-9500 (Telephone Number) he foregoing instrumentwas acknowledged Tbefore me this 26th day of September , 2019 by Lisa Rosegand as Attorney -In -Fact Aof The Ohio Casualty Insurance Company Surety, on behalf of Surety, He/She is rsnn known to me OR has produced N/A as identification and who did (did not take an oc- My Commission Expires; 04/12/2022 (S' nature) iyvs�'ry Notary Pcbho State of Flonda Name: Jenna Delgado `P Jenna Delgado - ' My Commission GG 364161 (Legibly Printed) w Expires o4/12/2022 ath. (AFFIX *Inquiries (407) 786-7770 Notary Public, State of; Florida Commission No.: GG 364161 r Tr �" 13 Construction Services Agreement: Revised 072118 C� U OR 5678 PG 1710 Bond No. 41K000110, executed in 2 counterparts Contract No. 19-7630 KNOW ALL MEN BY THESE PRESENTS: That Infinite Construction, LLC 6749 Idlewild St., Ft. Myers, FL 33966 (239) 823-6929, as Principal, and The Ohio Casualty Insurance Company ------------------------------------------ ----- as Surety, located at siness Address) are held and firmly bound to Board of County Commissioners of Collier County, Florida* , as Obligee In the sum of ($225,343.28------- )for the payment whereof we bond ourselves, cur heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered Into a contract dated as of the 27th WIN day of August 2019 1 with Obligee for Contract No l9omt7630 Barefoot Beach North Access Boardwalk and Pavilion Replacement,** in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal; 1. Performs the Contract at the times and !n the manner prescribed in the Contract; and 2. Pays Obligee any and all losses, damages, costs and attorneys' fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, ail delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time in specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this Bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions tc the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond, it is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not applyto this bond. In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this 26th day of September , 2019 ,the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. *15000 Livingston Road, Naples, FL 34109 (239) 2524020 **5901 Bonita Beach Rd., Bonita Springs, FL 34134 14 Construction Services Agreement: Revised 072118 C�u PG 1711 Signed, sealed and delivered In the presence of: 1-r-cP��u Flom-i ... , n . en Witnesse�/as to Principal M�Juel �lor'4, BY. NAME:_ ,),4N 1Z.ir��n s ITS: d)ner- STATE OF �"L.a��tflu • COUNTY OF .Lae The foregoing instrument was acknowledged before me this 774k day ofmlx� , 20 ict , by Pa„I ilc, VZ:*rt iAnC as Owner of In LL corporation, on behalf of the co to me OR has_produced identification an di did not) take an oath, he My Commission Expires: /ti►ct,a IGen-�1 (5ignature)v X\\111111111HII//,/]] Name: Minue�� 7 ��\��G�ss► kLO�`Fs�i�i� (Legibl tinted) (AFFIXj0FF1 f vS(= ` � Notary Public, State of: 'EL . * Commission No.: nc:-M(Mq 00 090179 .^ i4 b • � 16 Construcllon Services Agreement: Revised 072118 cA p OR 5678 PG 1712 ATTEST: Witnesses as to Surety Teresa L. Durham Witnesses Anita Navarra STATE OF Florida COUNTY OF Orange SURETY: The Ohio Casualty Insurance Company__.. _ (Printed Name) (Business Address) (Authorized Signature) (Printed Name) Attorney In Fact so (Attach Power of Attorney) �0 ; b �. .. 'fib �,A . •.• ol •�� . xtwlllkar-All -. u.,..,....1 _ !/)o 0l (Printed Name) Licensed Resident Agent* �'` •,,,,t� r�r„ �75 Berkeley Street + d Boston, MA _ 02116 (Business Address) (617)357-9500 (Telephone Number) The foregoing instrument was acknowledged before me this 26th day of September , 2019 , by Lisa Roseland , as Attorney -In -Fact Of The Ohio Casualty Insurance Company ,a New Hampshire Surety, on behalf of Surety, He/She is personally known to me OR has produced N/A as Idertificatiot)yind who did (rQt) take an path. My Commission Expires: 04/12/2022 �.aV PV. NNN�otary PubUc State of Florida Name; Jenna belgado me My Commission GG 304161 a W Expires 04112/2022 (AFFIX *Inquiries (407) 786-7770 re) (Legibly Printed Notary Public, State of; Florrda Commission No.: GG 364161 16 Construction Services Agreement• Revised 072118 Cq U *** OR 5678 PG 1713 *** "I`HIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. • - This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except In the manner and to the extent herein stated. - - _ : Certificate No 7990519 _ Liberty Mutual Insurance Company, - The Ohio Casualty Insurance Company West American irisurance Company_" - POWER OFATTORNEY, _ KNOWN ALL: PERSONS BY THESE PRESENTS, That The Ohio Ca"suafty Insurance Company is a corporation duly organized -under the laws of the Slate of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly, organized under the laws of the State of Indiana (herein collectively tailed the'Corripaniesl, pursuant to and by authority heren set forth, does hereby name, constitute and appoint; Mann Arvanitis_ Tarasa L. Durham: Lisa Roseland. Chervi Folev. Kim E. Niv: Susan L; Reich; Jeffrey W. Reich' Gloria A. Richards 'all of the city of Maitland state of FL each individually if there be more than one named, its true and lawful attorney-in•facl to make, execute, seal, acknowledge . and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons . 'IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or Official of the Companies and the corporate seals of the Companies have been affixed thereto this 25th day of January - 2018 ; tv PF' `��cy„No,;;A� - . _ , - The Ohio Casualty Insurance"Company N �e r t g Liberty Mutual Insurance Company 0 7919- o 1972 _ 1991 z _ West merican Insurance Company - U) ar+n:� �a� 'fli) �•+rR„m;�` ti T� oovw� t' - - - - .S] By _ STATE OF PENNSYLVANIA ` - ss = David M Care , Assistant Secretary m COUNTY OFMONTGOMERYPOOR o! dED On this 25th" day of January 2016 before me personally appeared David M Carey who"acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance v I --I v d Company, The Ohio Casualty Company, and West Amencan Insurance Company, and that he, as such, being authorized sd to do, execute the foregoing instrument for the purposes; >. � M•: '3 . .................. ... .. .i...,..,...... ,, :.,...ii ,.r .l... ., ....,...1...... tip. H.n. inn .... n .l„I„ nilhnn�nrl nfrnnr _ _ - - - - � t.ii L C a`r > IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written 0 o 3ERROR - - - 9P' PAST _ COMMONWEALTH OF PENNSYLVANIA Q M .a - - �, o onw�! For . , • ( Notarial Sool - 011 C '— f o - v 7oresa Pastnlla, Notary Puhhc _ BY I1�� O- - - - of I Upper MarionTwp„ Montgomery county Teresa Pastella, Notary Public 28- 3 N MINORr My Commission Expires March , 2021 vP�w I - - ' wto _ _ - Memtxfr, i?ennsylvanfaAssoclahon or Notaries O E_ CL Cd N This Power of Attorney is made and executed pursuant to and by authority of the following By-laws.and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual in e CDOR �, Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows, t,., OR ca ,�� ARTICLE IV— OFFICERS—Section-12 Power ofAttorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the Piesident,'and subject O m 14 s to such limitation as the OF or the President may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, ,� N o oEw acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations Such attomeys-intact, sublebt to the limitabons set forth in their respective E .y powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation, When so N p ` executed, such Insfruments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority gianted to any representative or altomey-in-fact under .> c R A the provisions of this article may be revoked at any time by the Board, the Chairman, -the President or by the officer or officers granting such power or authority i� N .a C ARTICLE XIII — Execution of Contracts -• SECTION 5 Surety Bonds and Undertakings Any officer of the Company authorized for that purpose in writing by the chairman or the president, E °Q > and subject tli such limitations as the chairman or the president may prescribe, shall appoint such attorneys-m-fact, as may be necessary to act in behalf of the Company to maker execute, t� M 0 V seat, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations; Such a@orheys-m-fact subject to the limitations set forth in their a co respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so L) Q executed such instruments shall be as binding as rf signed by the president and attested by the secretary. O Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attomeys-in- ~ fact as may be necessary to act behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, retiognizances and nd other surety obligations. Authorization ,, By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the - Company, wherever appeanng upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the,Company with_ the same force and effect as though manually affixed I, Renee C Llewellyn; the "undersigned, Assistant Secretary, The.Ohlo Casualty`insurentx; Company' Liberty Mutual Insurance Company, and West American Insurance Company'do hereby certify thatJj}e onginal power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is infull force and effect and has not beeA� 1 a - > > a V JOtt INrTEvSTI qq WR OF, I have hereunto set my hand and affixed the, sealg'gf slide Companies tilts- � day of S v...b 120 . ' iMst, ' `q. f ),Hsuirq Pawsu� Mate of FL QaRA ,._ N�ppq°�+,W ,il �yyr ti. 4Z.��veoa 'I'� '' i' tifGi'Lt.+�"""�",��+ `F c F a fo �w ^ ouu*7y= of C 11 YerAl e 1991 ? NEREBY CER4V IftYAT. thi$ jy ;a 'true y Rene LlevAll ssistantSecrelary _ odrAoerect co�jiit�of a doe`Lnt&nt�recorded_ _ �,d,ays° b .ems �r t7t,sg" t= _ aaAn� i'll fi* DOFF �I ECORDS of:.�'oTfier County �} * ys * w..UTNE�S my Train, r3hf`fTct31 oseal _ cv daft', 9(27/2019 +.Ld .: : CRYS:FALi KFNZgL. . ''ll4 .CLERKt,:OF 1HE�,{�MC.UT' �w=lT AND COMPTROLLER o'7j,Aa �t!`t `1 t� saollOO LMS_12873 022017- _ a- - EXHIBIT B-3: INSURANCE REQUIREMENTS The Contractor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida asset forth in EXHIBIT B of this solicitation. The Contractor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Contractor waive against each other and the County's separate Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Contractor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Contractors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number/contract number and title. The General Liability Policy provided by Contractor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Contractor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or, specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Contractor has any self -insured retentions or deductibles under any of the below listed minimum required coverage, Contractor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be Contractor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Contractor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation ornon-renewal on the part of the insurance carrier or the Contractor. The Contractor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or material change in coverage or limits received by Contractor from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Contractor hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 17 Construction Services Agreement: Revised 072118 Should at any time the Contractor not maintain the insurance coverages) required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage(s) and charge the Contractor for such coverage(s) purchased. If Contractor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Contractor under this Agreement or any other agreement between the County and Contractor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage(s) purchased or the insurance company or companies used. The decision of the County to purchase such insurance overage(s) shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Contractor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Contractor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 18 Construction Services Agreement: Revised 072118 Collier County, Florida Insurance and Bonding Requirements Insurance! Bond Type Required Limits 1. ® Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Governmeint. Statutory Limits and Requirements Tividence of WorkersCompensation, cover age; or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof`of exemption. An application l'or exemption can be obtained online at iittl�s:llitpps.ildls.catnlbocexcn 2. ®Employer's Liability $1,000,000 single limit per occurrence ^,. ®Commercial General 13adily Injury and Property namage Liability (Occurrence Fortn) patterned after the current $11000,000 single limit per occurrence, $2,000,000 aggregate for Bodily Injury Liability ISO form anti. Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. =I. ❑X Indemnification •I'o the maximum extent permitted. Uy Florida law, the ContractorlVendor shall defend, indemnify and hold harmless Collier County; its officers and employees ftom any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor/ Vendor or anyone employed or utilized by the Contractor/Vendor in the performance of this Agreement. 5. ©Automobile Liability 51,000,000 Each Occurrence; Bodily Injury & Pro_perty Damage, Owned/Non-owned/.Hired; Automobile Included 6. ❑Other insw•ance as noted: ❑ Watercra43 $ Yer Occurrence ❑ United States Longshorennan's and HarUorworker`s Act coverage shall be maintained where applicable to the completion oi'the wank. $ Per Occurrence ❑ Maritime Coverage (.loves Act) shall be maintained where applicable to the cotnplction of the work. $ Per Occurrence Aircraft Liability coverage shall be carried in limits of not less than $5,000,000 each accurrence if applicable to the completion of the Services under this Agreement. S Per Occurrence ❑ :Pollution. $ -- -.-Per Occurrence ❑ Professional I.,iability $ _.._ Per claim & in the aggregate ❑ Project Professional Liability Per Occurrence ❑ Valuable Papers Insurance S.. Per Occurrence ❑ Cyber LiabilityPer Occurrence ❑ Tcchtnology Errors m. Onnissions S T'er Occurrence 19 Construction Services Agreement: Revised 072118 7. ® Bid bond Shall be submitted with proposal response in the form of certified funds, cashierscheck or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Boar1 of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. ®Performance and For projects in excess of $200,000, bonds shall be submitted with the executed contract Payment Bonds by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Sheet, New York, New York 1003 8. 9. ® Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. 10. Q Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Vendor's policy shall be endorsed accordingly. 11. ® The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12. ® On all certificates, the Certiftcate Holder must read: Collier County Board of Commissioners, 3295 Tamiami Trail East, Naples, FL 34112 13. ®Thirty (30) Days Cancellation Notice required. 14. Collier County shall procure and maintain Builders Risk Insurance on all construction projects where it is deemed necessary. Such coverage shall be endorsed to cover the interests of Collier County as well as the Contractor. Premiums shall be billed to the project and the Contractor shall not include Builders Risk premiums in its project proposal or project billings. All questions regarding Builder's Risk Insurance will be addressed by the Collier County Risk Management Division. 6/18/19 - CC Vendor's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. The insurance submitted must provide coverage for a minimum of six (6) months from the date of award. Name of Firm Vendor Signature Print Name Insurance Agency Agent Name �"_cit'is"'r�C.�-� r`r Date lr'�i � ��t?l`y-� i F'3 [ t'�:.'«�,.�, lY1`�si?ti/1f"t� z`�{o,.t,.�• ;„�nn.,x �._�,.. _.—_-- Telephone Number 20 Construction Services Agreement: Revised 072118 /"'y ``t Cl EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF (COLLIER) STATE OF (FLORIDA) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. Witness President Witness STATE OF COUNTY OF CONTRACTOR BY: ITS: DATE: [Corporate Seal] The foregoing instrument was acknowledged before me this day of , 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me or has produced as identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) NAME: (Signature of Notary) (Legibly Printed) blic Notary Pu, State of Commissioner No.: 21 Construction Services Agreement: Revised 072118 EXHIBIT D FORM OF CONTRACT APPLICATION FOR PAYMENT Collier Count Board of Count Commissioners the OWNER or Collier Count Water -Sewer Owner's Project Manager's Name: Bid No. Project No. Count 's Division Name Purchase Order No. Submitted by Contractor Representative: Name Application Date: Contractor's Name & Address: Payment Application No. Original Contract Time: Original Contract Price: $ Revised Contract Time: Total Change Orders to Date: $ Revised Contract Amount: $ Total Value of Work Completed & Stored to Date: $ Retainage @10% through [Insert Date] $ Retainage @ 10% through [Insert date] $ Retainage @ % after Insert datell $ Less Retainage $ Total Earned Less Retainage $ Less previous payment(s Percent Work Completed to Date: % AMOUNT DUE THIS APPLICATION: $ Percent Contract Time Completed to Date: % Liquidated Damages to Be Accrued $ Remaining Contract Balance $ ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. Contractor's Name Contractor's Si nature: Date: Type Title: Shall be signed by an authorized re resentative of the Contractor. Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Design Professional's Name: Signature: Date: Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Owner's Project Manager Name: Si nature: Date: 22 Construction Services Agreement: Revised 072118 EXHIBIT D (Continued) SCHEDULE OF VALUES ITEM NUMBER DESCRIPTION SCHEDULED VALUE WORK COMPLETED STORED MATERIALS TOTAL COMPLETEC &STORED TO DATE PERCENT COMPLETE BALANCE TO FINISH 70% RETAINAGE _/ RETAINAGE (reducedrme) TOTAL RETAINAGE WITHHELD PREMOUS APPLICATIONS THRU DATE SINCE DATE THIS PERIOD TOTALS • Explanation for the two columns under Previous Applications: The Thru Date is where you will place all information until the contract is complete unless a release or reduction of retainage issue cor into play. If this happens, all information up to the date of the % change in retainage is placed in the Thru Date col..umn Information after that date is placed in the Since Date column. This states ... . _. what has happened since the change in retainage. 23 Construction Services Agreement; Revised 072118 Exhibit D (Continued) Stored Materials Record Formula:A+B-C-D=E A B C D E Date Description Supplier Invoice Number Previously Received Received This Period Previously Installed Installed This Period Balance To Install 24 Construction Services Agreement: Revised 072118 EXHIBIT M. CHANGE ORDER An electronic data entry form may be found at: http:HbccspO1 /SiteDirectory/ASD/Purchasing/Forms1 /Forms/DefauIt.aspx Change Order Form Contract#: Changer L purchase Order#: �� Project ContractorlFirm Name: Project Name: �— Project Manager Namel Department: insl CanirsctFdVcrr Coder Amount Crqinsl 6CC Apgrevsl Data; Agenda. Item Currant BCC Aporol asd Amount last BCC Approval DstE; Agenda Item# Current Contr,adrvAt o(k Crd=_r Amount SAP Contract Expiration Date f Nisster) Do16r Am ountof th's Change 00 IWO! Total Chsnge if cm Or ig I ns I An-cu nt Rs via edCcntractsVoT'K Of der Total S 0.00 ? ?IV,+DI ChsngefmmCLrrent BCC Approved Amount C:urcujlgiix�Chsnoas S nnol r fUlili`J! ChangefromCurrentAmount_.. ... Completion Da#g, Description cf the Taskfs} Change, and Rationale fer the Change Notice to Proc L J original le Last Approved �� Revised Date Date Completion Da t Date tKs��e:� if of Days Added Select Tasks I1 Addnewtaskfs) fl Deletetask(s) L7'Changetask(s) eo OtherttssMjiat Prcvid a a resp on se to the following:1.) detailed and specific explanationkationaie of the requested change(s) to the task(s) and I or the additional days added (if requested}:2.,)why this change was not included in the original contract and, 3) describe the impact if this change is not processed. ktt c?s a=:"3tionai anfcrma3 or from th? D-ai;r- I?rof�;_i7ral ar tlar Co rtracior rF r.__. Ptepatetl by: Date: f,Proye€-t lrlaraazr Nam. and DeF?rtmzrt} Aec eptancz of t his Ctangz Order shall ccrstftuz_ a mxxJiica6or to cor==tta;t f :rrerk order ldeni ifiaf above and v+ifi t? 5c bj=t;'! to a91 the cant= termsan3corcitiarsa=_c+sntaira;ir.thecortraci:i'vxorl:cra�rir3icatedabove, asfully asifthe sartz•taste=_iata3inthisac�fitatrce. The adjusimzri, if ary, i+. the Contra?# shall car-si irate a fu it and firal snit Ierner€t 4i any ans ail claims of the Contractor i Vzrdnr F Corsukant 7 DesgrProfessional a(is irgcutoforr_ct3#fStothechar tsetforth hierem,irx:ludirgclaimsfor impact and delaycosts. Accepted by: Date: , (Contractor, Nervdor F Consu3tart I Dzsigrs Prcf_ssioral ar•3 flame of Firm, if prof �tappiieabiz) Approved by: Lutz: fDesgrProfessional and Name of Firm, if projectapplrab!;) Approved by: Dots: fPrc��urerrrant Profzssi<anai 25 Construction Services Agreement: Revised 072118 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date Design Professional's Project No. This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 26 Construction Services Agreement: Revised 072118 RESPONSIBILITIES: OWNER: CONTRACTOR The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on By: Design Professional Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 By: CONTRACTOR Type Name and Title OWNER accepts this Certificate of Substantial Completion on By: OWNER Type Name and Title 20 20 z� Construction Services Agreement: Revised 072118 EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: Contractor: The following items have been secured by the for the Project known as PO No.: Date: and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner (attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As -Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14, Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: (Company Name) (Signature) (Typed Name & Title) By Design Professional: (Firm Name) (Signature) (Typed Name & Title) By Owner: (Department Name) (Signature) (Name & Title) 2s Construction Services Agreement: Revised 072118 EXHIBIT H: GENERAL TERMS AND CONDITIONS 1. INTENT OF CONTRACT DOCUMENTS. 1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and installed as part of the Work, whether or not called for by the Contract Documents. 2. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power, availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work -site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 2s Construction Services Agreement: Revised 072118 t�� 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub -Section 2.2 as the "Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. 3. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of .Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time, The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be 30 Construction Services Agreement: Revised 072118 C`�Cl limited to the hours of 7 a.m. to 7 p.m., Monday through Saturday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.4 Contractor shall submit its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 4.5 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re -submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is 31 Construction Services Agreement: Revised 072118 stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255,078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent (50%) completion subject to the guidelines set forth in Florida Statute 255,078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub -subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub -subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non- payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 32 Construction Services Agreement: Revised 072118 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents, The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non -liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5.3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off -set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit I 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 33 Construction Services Agreement: Revised 072118 e� � 7. SUBMITTALS AND SUBSTITUTIONS. 7A Contractor shall carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.z Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will 34 Construction Services Agreement: Revised 072118 record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub -Contractor's personnel; 8.1.4 The number of Contractor's and Sub -Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 8.1.7 8.1.8 8.1.9 8.1.10 of performance. Description of Work being performed at the Project site; Any unusual or special occurrences at the Project site; Materials received at the Project site; A list of all visitors to the Project Any problems that might impact either the cost or quality of the Work or the time The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features 35 Construction Services Agreement: Revised 072118 (e.g. interior or exterior all faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The "As -Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As -Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documeritation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112=5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Pubic Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 9. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material -men, as well as coordinating its Work with all 36 Construction Services Agreement: Revised 072118 work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner'is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders, The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change. Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in on written Work 37 Construction Services Agreement: Revised 07211 S Directive. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub -subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or sub -subcontractor for field and home office overhead is included in the markups noted above. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight (48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pendency of any Claim. 38 Construction Services Agreement: Revised 072118 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work'with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the Contractor/Vendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentional y wrongful conduct of the ContractorNendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnifyI and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit B23 to the Agreement. 39 Construction Services Agreement: Revised 072118 Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit 13-3. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes), If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreementto be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et se , and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (&Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet - based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: • Commodity based procurement where no services are provided. • Where the requirement for the affidavit is waived by the Board of County Commissioners Contractors /Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Contractor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed &Verify Memorandum of Understanding for the company. Contractors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. MM evidence and the executed affidavit the bidder's /Contractor's proposal may be deemed non- responsive. 40 Construction Services Agreement: Revised 072118 Additionally, Contractors shall require all subcontracted Contractors to use Lite E-Verify system for all purchases not covered under the "Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (&Verify) program visit the following website: http://www.dhs.gov/E-Verify. It shall be the Contractor's responsibility to familiarize themselves with all rules and regulations governing this program. Contractor acknowledges, and without exception or stipulation, any firms) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seed. , and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2.3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies when the Contractor is acquiring permits. Owner will not be obligated to pay for any permits obtained by Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 41 Construction Services Agreement: Revised 072118 ,� 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default of the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s) within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials, equipment, supplies, and other items therefore or re -letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 42 Construction Services Agreement: Revised 072118 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below. 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonabletime thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager 43 Construction Services Agreement: Revised 072118 -try shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch -list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch -list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: (1) Receipt of Contractor's Final Application for Payment. (2) The Release and Affidavit in the form attached as Exhibit C. (3) Consent of surety to final payment. (4) Receipt of the final payment check list. (5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 44 Construction Services Agreement: Revised 072118 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 2203 Contractor is responsible, without reimbursement from Owner, for re -inspection fees and costs; to the extent such re -inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered withoutwritten concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight (8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shall as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non -defective Work. Contractor shall bear all direct, indirect and consequential 45 Construction Services Agreement: Revised 072118 costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstruction. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall 46 Construction Services Agreement: Revised 072118 include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit X1 is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a- penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.8, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner oI Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor new or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time, 47 Construction Services Agreement: Revised 072118 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, 48 Construction Services Agreement: Revised 072118 Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28,5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5.7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5.9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend apre-construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or 49 Construction Services Agreement: Revised 072118 Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre -construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right -of -Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.nettpurchasing. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work ("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of 50 Construction Services Agreement: Revised 072118 the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be "qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self -performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33A Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub -subcontractor performing any portion of the Work, as well as maintain a log of all such licenses. All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of 51 Construction Services Agreement: Revised 07211 S Owner upon termination of Contractor, (3) provide that Ownerwin be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third -party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its sub - subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on -site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor (including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be caused by Owner or Design Professional or attributable to Owner or Design Professional and including claims based on breach of contract or negligence, shall be an extension of its contract time. 33.6.2 In the event of a change in the work, the Subcontractor's claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus no more than 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub -subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims . by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner, and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 52 Construction Services Agreement: Revised 072118 34.1.3 Shop Drawing Submittal/Approval Logs 34A A Equipment Purchase/Delivery Logs 34.1.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 34.1.10 Equipment Costs 34.1 A 1 Cost Proposal Request 34.1 A 2 Payment Request Records 34.1.13 Meeting Minutes 3401014 Cost -Estimates 3401015 Bulletin Quotations 3441016 Lab Test Reports 34.1.17 Insurance Certificates and Bonds 3401018 Contract Changes 34.1.19 Permits 34.1020 Material Purchase Delivery Logs 3461,21 Technical Standards 34.1022 Design Handbooks 34.1.23 "As -Built" Marked Prints 34.1.24 Operating & Maintenance Instruction 34.1525 Daily Progress Reports 34.1.26 Monthly Progress Reports 34.1627 Correspondenoe Files 3401928 Transmittal Records 34.1.29 Inspection Reports 34.1.30 Punch Lists 3401031 PMIS Schedule and Updates 34.1.32 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the presentation requirements and format. Presentations may include, but not be limited to, the following information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shall be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County 53 Construction Services Agreement: Revised 072118 under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via a -mail (DL-FMOPSO)colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of $500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the Contractor is responsible for all costs. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A "project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid & Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing / will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48-hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials / petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 54 Construction Services Agreement: Revised 072118 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision - making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision -making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44,102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 55 Construction Services Agreement: Revised 072118 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS 56 Construction Services Agreement: Revised 072118 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES FEDERAL, EMERGENCY MANAGEMENT AGENCY PUBLIC ASSISTANCE This project activity is funded in whole or in part by the Federal Government, or an Agency thereof. Federal Law requires that the Applicant's contracts relating to the project include certain provisions. Per uniform requirements of federal awards (2 CFR Part 200,23) the definition of CONTRACTOR is an entity that receives a contract (including a purchase order). Compliance with Federal Law, Regulations and Execu#ive Orders: The Sub -Recipient (County) agrees to include in the subcontract that (I) the subcontractor is bound by the terms of the Federally -Funded Subaward and Grant Agreement, (ii) the subcontractor is bound by all applicable state and Federal laws and regulations, and (iii) the subcontractor shall hold the Division and Sub -Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. Specifically, the Contractor shall be responsible for being knowledgeable and performing any and all services under this contract in accordance with the following governing regulations along with any and all other relevant Federal, State, and local laws, regulations, codes and ordinances: t7 2 C.F.R, Part 200 Uniform Administrative. Requirements, Cost Principles, and Audit Requirements for Federal Awards 44 C.F.R. Part 206 o The Robert T. Stafford Disaster Relief and Emergency Assistance Act, Public Law 93- 288, as amended, 42 U.S.C. 5121 et seq., and Related Authorities o FEMA Public Assistance Program and Policy Guide, 2017 (in effect for incidents declared on or after April 1, 2017) Reporting: The contractor will provide any information required to comply with the grantor agency requirements and regulations pertaining to reporting. It is important that the contractor is aware of the reporting requirements of the County, as the Federal or State granting agency may require the contractor to provide certain information, documentation, and other reporting in order to satisfy reporting requirements to the granting agency. Access to Records: (1) The contractor agrees to provide the County, the FEMA Administrator, the Comptroller General of the United States, or any of their authorized representative's access to any books, documents, papers, and records of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts, and transcriptions. (2) The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. (3) The contractor agrees to provide the FEMA Administrator or his authorized representatives' access to construction or other work sites pertaining to the work being completed under the contract. DNS Seal, Logo, and Flags: The contractor shall not use the DHS seal(s), logos, crests, or reproductions of flags or likenesses of DHS agency officials without specific FEMA pre- approval. No Obligation by Federal Government: The Federal Government is not a party to this contract and is not subject to any obligations or liabilities to the non -Federal entity, contractor, or any other party pertaining to any matter resulting from the contract. Program Fraud and False or Fraudulent Statements or Related Acts: The contractor acknowledges that 31 U.S.C. Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the contractor's actions pertaining to this contract. EXHIBIT I -1 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES Energy Efficiency Standards: The contractor agrees to comply with mandatory standards and policies relating to energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy and Conservation Act. Termination: Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be sole judge of non-performance. In the event that the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the Agreement Amount earned through the date of termination. The Contractor shall not be entitled to any other or further recovery against the County, including, but not limited to, any damages or any anticipated profit on portions of the services not performed. Rights to Inventions Made Under a Contract or Agreement; If the Federal award meets the definition of "funding agreement" under 37 CFR §401.2 (a) and the County wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that "funding agreement," the County must comply with the requirements of 37 CFR Part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by the awarding agency. Changes: See Standard Purchase Order Terms and Conditions. Procurement of Recovered Materials (§200.322) (Over $90,000): (1 } In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA designated items unless the product cannot be acquired (i) Competitively within a timeframe providing for compliance with the contract performance schedule; (H) Meeting contract performance requirements; or (III) At a reasonable price. (2) Information about this requirement is available at EPA's Comprehensive Procurement Guidelines web site, https:/iwww epa govismmlcomprehensive-procurement-ctuideline-cpg t.�rac,�ain Suspension and Rebarment: (1 }This contract is a covered transaction for purposes of 2 C.F.R. pt. 180 and 2 C.F.R, pt. 3000. As such the contractor is required to verify that none of the contractor, its principals (defined at 2 C.F.R. § 180,995), or its affiliates (defined at 2 C.F.R. § 180.905) are excluded (defined at 2 C.F.R. § 180.940) or disqualified (defined at 2 C.F.R. § 180.935). (2) The contractor must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into. (3) This certification is a material representation of fact relied upon by the County. If it is later determined that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, in addition to remedies available to the County, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. (4) The bidder or proposer agrees to comply with the requirements of 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions. Contracting with small and minority businesses, women's business enterprises, and labor surpl s area firms §200.324t (a) The Solicitor must take all necessary affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whenever possible. (b) Affirmative steps must include: (1) Placing qualified small and minority businesses. and women's business enterprises on solicitation lists; (2) Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; EXHIBIT I - 2 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES (3) Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; (4) Establishing delivery schedules, where the requirement permits, which encourage participation by small and minority businesses, and women's business enterprises; (5) Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce; and (6) Requiring the prime contractor, if subcontracts are to be let, to take the afifirmative steps listed in paragraphs (1) through (5) of this section. Equal Employment Opportunity Clause (§60-1.4): Except as otherwise provided under 41 C.F.R. Part 60, all contracts that meet the definition of "federally assisted construction contract" in 41 C.F.R. § 60-1.3 must include the equal opportunity clause provided under 41 C.F.R. § 60- 1.4. During the performance of this contract, the contractor agrees as follows: The contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment, or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. ll. The contractor will, in all solicitations or advertisements for employees placed by or on behalf of the contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. III. The contractor will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the contractor's legal duty to furnish information. IV. The contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workersrepresentative of the contractor's commitments under section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. V. The contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. EXHIBIT I - 3 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES Vl. The contractor will furnish all information and reports required by Executive Urder 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. VII. In the event of the contractor's non-compliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be canceled, terminated or suspended in whole or in part and the contractor may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor; or as otherwise provided by law. VI(1. The contractor will include the provisions of paragraphs (1) through (8) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The contractor will take such action with respect to any subcontract or purchase order as may be directed by the Secretary of Labor as a means of enforcing such provisions including sanctions for noncompliance: Provided, however, that in the event the contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction, the contractor may request the United States to enter into such litigation to protect the interests of the United States. Contract Work Hours and Safe#y Standards Act (40 U.S.C. 3701.3708) (over $100,000): Where applicable, all contracts awarded by the solicitor in excess of $100,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). {1) Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek. (2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1) of this section. (3) Withholding for unpaid wages and liquidated damages. The (write in the name of the Federal agency or the loan or grant recipient) shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally -assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2) of this section. EXHIBIT 1 - 4 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES {4) Subcontracts. The contractor or subcontractor small insert in any subcontracts the clauses set forth in paragraph (1) through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1) through (4) of this section." Administrative, Contractual, or Legal Remedies (over $150,000): Unless otherwise provided in this contract, all claims, counter -claims, disputes and other matters in question between the local government and the contractor, arising out of or relating to this contract, or the breach of it, will be decided by arbitration, if the parties mutually agree, or in a Florida court of competent jurisdiction. Clean Air Act and Federal Water Pollution Control Act: (over $150,000) (1) The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. § 7401 et seq. (2) The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq. (3) The contractor agrees to report each violation to the County and understands and agrees that the County will, in turn, report each violation as required to assure notification to the Federal Emergency Management Agency, and the appropriate Environmental Protection Agency Regional Office. (4) The contractor agrees to include these requirements in each subcontract exceeding $150,000 financed in whole or in part with Federal assistance provided by FEMA. Byrd Anti -Lobbying Amendment (31 U.S.C. § 1352 (as amended) (over $100,000): Contractors who apply or bid for an award of $100,000 or more shall fide the required certification. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant, or any other award covered by 31 U.S.C. § 1352. Each tier shall also disclose any lobbying with non -Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier upto the recipient." State Provisions Convicted Vendor and Discriminatory Vendors List Those who have been placed on the convicted vendor list following a conviction for a public entity crime or on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with a public entity, and may not transact business with any public entity in excess of $25,000.00 for a period of 36 months from the date of being placed on the convicted vendor list or on the discriminatory vendor list. Lobbying: No funds received pursuant to this Agreement may be expended for lobbying the Legislature, the judicial branch or any state agency. Inspector General Cooperation: The Parties agree to comply with Section 20.055(5), Florida Statutes, for the inspector general to have access to any records, data and other information deemed necessary to carry out his or her duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5), Florida Statutes. Record Retention - The contractor shall maintain and retain sufficient records demonstrating its compliance with the terms of the Agreement for a period of at least five (5) years after final payment is made and shall allow the County, FDEM, or its designee's access to such records upon request. EXHIBIT I - S EXFiiBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES Acknowledgement of Terms, Conditions, and Grant Clauses Certification If the vendor subcontracts any of the work required under this Agreement, a copy of the signed subcontract must be available to the Department for review and approval. The vendor agrees to include in the subcontract that (1) the subcontractor is bound by the terms of this Agreement, (ii) the subcontractor is bound by all applicable state and federal laws and regulations, and (ill) the subcontractor shall hold the Department and Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. The recipient shall document in the quarterly report the subcontractor's progress in performing its work under this agreement. For each subcontract, the Recipient shall provide a written statement to the Department as to whether the subcontractor is a minority vendor as defined in Section 288.703, Fla. Stat. On behalf of my firm, I acknowledge, the grant requirements identified in this document. Vendor/Contractor Name Authorized Signature EXHIBIT I - 6 EXHIBIT 1 FEDERAL CONTRACT PROVISIONS AND ASSURANCES CERTIFICATION REGAI'2DiNG REBARMENT, SUSPENSION, INELIGIBILITY and VOLUNTARY EXCLUSION Contractor Covered Transactions (I) The prospective subcontractor ofi the Sub -recipient, Collier County, certifies, by submission of this document, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency. (2) Where the Sub -recipient's subcontractor is unable to certify to the above statement, the prospective contract shall attach an explanation to this farm. CONTRACTOR By: Signature (� � •, �-y Name and Title �� C�`�"zi�'d i,�tl,��.� �I� Street Address City, State, Zip �_ / �� i."�r)�� I'�i I DUNS Number Date Sub -Recipient Name; Collier County Board of County Commissioners DEM Contract Number: Z0001 FEMA Project Number: 4337DRFLP0000001 EXHIBIT I - 7 ��'� CJ EXHIBIT I GPnPPAI MNITRArT PROVISIONS AND ASSURANCES Ct31.LI ER CO U%!TY ANTICIPATED DISADVANTAGED, MINt?RITY, WE;MEN aR VETERAN PARTI.IPATIt3N STATEMENT will be =rifled, UrwerF'aULL statuses will require the PRME to either presvde a revised statement orpro qde source documentation that validates a i PRIME NAME PRIME FUD EWP(MER CONTA, CT Di]LLdR:�htOUCiT 11 tt IS THE PRIME AFLOR1DA•CERTIFIEDDISAS AlfrAGED, yg(ERSN Y ChJ� 6THEA41TIV1TY0FTH15CONTRACT,.. MINORITYORWOMEN BUNINUSENTURLSV DBE? Y C t. > COt•15TP,UGTION ? CD 14 (ME/i DEMBE) ORHA\rASMAIIDI5.ADVANTAGED ? Y %ASE. CANSULTATON? Y <.td BUS114ESSSACERTICATIONfR014THE5tALLBUSINE_S OTHER? Y IQ� ADMINISTP,ATION? A:SERVICEDMAELEOVEFERAN? WBE? Y {N-j 3DB CA? Y (f3) IS THIS SUBt.51SS:Oit 32EVI510N? Y (`tJ� F YES REVISION NUMBER IF PRIME. HASSUBCONTRA(TOR UPPUER'WHO IS A MADVANTADED MENOR1TYf WQMEN OWNED SItt7ALl ORS B, BUSINESS CONCERN QR 5ERVCtE DISABLED \VETERAN, PRIME IS TO C,OMPLETETfiI5 NEXTSfCTIQN EXHit31 I I - t5 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES LOBBYING CERTIFICATION (To,be submitted with each bid;or offer exceeding $100,060) The undersigned [Contractor] certifies, to the best of his or her knowledge, that: 1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. 2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form- LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions. 3. The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including subcontracts, subgrants, and contracts under grants, loans, and cooperative agreements) and that all subrecipients shall certify and disclose accordingly. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making o, entering into this transaction imposed by 31, U.S.C. § 1352 (as amended by the Lobbying Disclosure Act of 1995). Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The Contractor certifies or affirms the truthfulness and accuracy of each statement of its certification and disclosure, if any. in addition, the Contractor understands and agrees that the provisions of 31 U.S.C. § 3801 et seq., apply to this certification and disclosure, if any. Contractor (Firm Name) Signature of Contractor's Authorized Official Name and Title of Contractor's Authorized Official Date EXHIBIT I - 9 INFINA OP ID: JM ACORO" CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) `- 08/27/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER, THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER, IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsements . PRODUCER 727-360-0092 NCO TACT Patrick Higgins ISU Coast To Coast Insurance PHONE 727.360-0092 FAX Services, LLC (A/C, No, Ext): (A/C, No): 630 Corey Ave A-DmDAIE • prh@)Iongshoreins.com Saint Pete Beach, FL 33706 Patrick Higgins INSURERS AFFORDING COVERAGE NAIC # INSURERA:RLI Insurance Company 13056 IN URED INSURERB:PMA Insurance 36897 6749 Id Construction, LLC American Lon shore Mutual Asso 6749 Idlewild Street INSURER C : Long shore Myers, FL 33966 wsuReR D . Lloyds of London CCIVFRA�FS rFRTtGIr:ATF NI IMRFR• INSURER F THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, INSR TYPE OF INSURANCE DDL UBR POLICY NUMBER POLICY EFF POLICY EXP LIMITS A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 11000,000 � OCCUR Y MLP0200360 07/27/2019 07/27/2020 DAACLAIMS-MADE PREMI TO ( a occcu r ce $ 50 000 MED EXP (Any oneperson) $ 51000 PERSONAL & ADV INJURY $ 150001000 GEN'L AGGREGATE LIMIT APPLIES PER: X POLICY ❑ JECT LOC GENERALAGGREGATE $ 21000,000 PRODUCTS - COMP/OP AGG $ 11000,000 OTHER: AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ ANY AUTO OWNED SCHEDULED BODILY INJURY Perperson) $ AUTOS ONLY AUTOS BODILY INJURY Per accident $ PROPERTY AMAGE Per accident $ HIRED NON -OWNED AUTOS ONLY AUTOS ONLY UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS -MADE AGGREGATE $ DED RETENTION $ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? N (Mandatory in NH) N / A 1022557Y 07/27/2019 07127/2020 X PER E OTRH- E.L. EACH ACCIDENT 120001000 $ E.L. DISEASE - EA EMPLOYE $ 11000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT 1 OUO OUO $ C USL&H ALMA02038-02 07/27/2019 07/27/2020 USL&H 1,0001000 D Maritime Empl Liab 19L125BC2402 01/28/2019 01/28/2020 MEL 1,0001000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space Is required) SEE NOTES: Collier County Board of County Commissioners 3295 Tamiami Trail E. Naples, FL 34112 COLCBCC SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) ©1988-2015 ACORD CORPORATION. Ali rights reserved. The ACORD name and logo are registered marks of ACORD .a`oEzn° CERTIFICATE OF LIABILITY INSURANCE DATE (M17R1pDIYYYY) 11/13/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER, THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER, IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the pollCy(ies) must have ADDITIONAL INSURED provisions or be Endorsed, IfSUBROGATION IS WAIVED, subject to the terms and Conditions of the policy, certain policies may require an endorsement, A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement s). PRODUCER CONTACT Ann Clark i]a' 1.1- is Ti I Ann Clark PHONE 239 433 7771 PAx 16440 S Tamiami Trl. E�1Aa AIC Ne : 239-433-7771 �.' ADORE s: ann.clark.bxkh(gistatefarm.com Fort Myers, FL 33908 ,flu 1w0wVeJVA1JC NATC If INSURED INSURERA: State Farm Mutual Automobile Insurance Company 25178 INFINITE CONSTRUCTION, LLC INSURER B : Paulius Kidlinas INSURER C : 6749 IDLEVJILD ST INSURER D: FORT MYERS INSURER E : 33966 INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES, LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, INSR ADDL SUBR LTR TYPEOFINSURANCE POLICY NUMBER POLICY EFF &VDDff XP rafa/DO/YYVy M/DOIYYYY COMMERCIAL GENERAL LIABILITY umns EACH OCCURRENCE S CLAI.NS-MADE OCCUR OAMA T ENTED I PREMISES Ea occurrenoel S MED EXP (Any we parson) 5 PERSONAL B ADV INJURY 5 GEN-LAGGREGATE UMIT APPLIES PER. POLICY 1RO- LOC GENERAL AGGREGATE 5 JECT OTHER PRODUCTS-COMP/OPAGG 5 AUTOMOBILE LVIBWN S Y E954787-E07-59 I11/07/2019 05/07/2020 COMBINEDSINGLE LIMIT ANY AUTO Ea accident 5 1,000,000 B O'ANED SCHEDULED BODILY INJURY(Perperson) § AUTOS ONLY AUTOS BODILY INJURY (Per accident) S HIRED NON -OWNED AUTOS ONLY AUTOS ONLY PROPERTY DAMAGE $ For aodd t S UMBRELLA uA8 OCCUR EXCESS LIAB CLAIMS -MADE EACH OCCURRENCE § § OED RETENTION AGGREGATE WORKERS COMPENSATION 5 AND EMPLOYERS' LIABILITY PER Or ANY PROPRIETOR/PARTNER/EXECUTIVE YIN STATUTE ER OFFICER/AIEMac'R EXCLUDED? ❑ NIA EL EACH ACCIDENT S (Mandatory In NH) If qq s, describe under EL DISEASE -EA EMPLOYE S ❑ESCRIP ION OF OPERATIONSF.elornv E.L. DISEASE -POLICY LIMIT S DESCRIPTION OF OPERATIONS/ LOCATIONS IVEHICLES (ACORD 101, Additonal Remarks Schedule, may be attached If more space is required) Barefoot Beach North Access Boardwalk and Pavilion Replacement ITB#19-7630 CERTIFICATE HOLDER r A kl n, , �,,,,, SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Collier County BoarTl of County Commissioners ACCORDANCE WRH THE POLICY PROVISIONS. 3295 Tamiami Trail E. Naples FL, 34112 AUTHORIZED REPRESENTATIVE t � L 1 1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD 10014E5 732049.72 03-762016