Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Backup Documents 12/14/2021 Item #16C2
ORIGINAL DOCUMENTS CHECKLIST & ROUTING SLIP 1 6 C Z TO ACCOMPANY ALL ORIGINAL DOCUMENTS SENT TO THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR SIGNATURE Print on pink paper. Attach to original document. The completed routing slip and original documents are to be forwarded to the County Attorney Office at the time the item is placed on the agenda. All completed routing slips and original documents must be received in the County Attorney Office no later than Monday preceding the Board meeting. **NEW** ROUTING SLIP Complete routing lines#1 through#2 as appropriate for additional signatures,dates,and/or information needed. If the document is already complete with the exception of the Chairman's signature,draw a line through routing lines#1 through#2,complete the checklist,and forward to the County Attorney Office. Route to Addressee(s) (List in routing order) Office Initials Date 1. Risk Risk Management 67 /zip/( u 2. County Attorney Office County Attorney Office C, fr I3- 15 1 4. BCC Office Board of County fir ,by Commissioners 4a, Icy 406/0(/ 4. Minutes and Records Clerk of Court's Office -2=37� 5. Procurement Services Procurement Services PRIMARY CONTACT INFORMATION Normally the primary contact is the person who created/prepared the Executive Summary. Primary contact information is needed in the event one of the addressees above,may need to contact staff for additional or missing information. Name of Primary Staff Patrick O'Quinn'PURCHASING Contact Information 239-252-8407 Contact/ Department Agenda Date Item was December 14, 2021 t / Agenda Item Number 16.C.2. Approved by the BCC Type of Document Professional Services Agreement Number of Original 1 Attached Documents Attached PO number or account N/A 21-7904 Johnson number if document is Johnson Engineering, Inc. to be recorded Engineering, Inc. INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable column,whichever is Yes N/A(Not appropriate. (Initial) Applicable) 1. Does the document require the chairman's original signature, AMP OI N/A 2. Does the document need to be sent to another agency for additional signatures? If yes, N/A provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be AR signed by the Chairman,with the exception of most letters,must be reviewed and signed by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the AR document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's AR signature and initials are required. 7. In most cases(some contracts are an exception),the original document and this routing slip N/A should be provided to the County Attorney Office at the time the item is input into SIRE. Some documents are time sensitive and require forwarding to Tallahassee within a certain time frame or the BCC's actions are nullified. Be aware of your deadlines! 8. The document was approved by the BCC on December 14,2021 and all changes made RECEIT' .u' during the meeting have been incorporated in the attached document. The County ►�i;ion for Attorney's Office has reviewed the changes,if applicable. t ne. DEC 14 9. Initials of attorney verifying that the attached document is the version approved by the is not BCC,all changes directed by the BCC have been made,and the document is ready for the C/ ' an option for Chairman's signature. lisk a ' Vie. i 16C2 MEMORANDUM Date: December 16, 2021 To: Patrick O'Quinn, Purchasing Procurement Services From: Martha Vergara, Sr. Deputy Clerk Minutes & Records Department Re: Contract #21-7904 for "Professional Services Agreement" Contractor: Johnson Engineering, Inc. Attached for your records is an original of the referenced document above, (Item #16C1) adopted by the Board of County Commissioners on Tuesday, December 14, 2021. The Board's Minutes & Records Department has kept an original as part of the Board's Official Records. If you have any questions, please feel free to contact me at 252-7240. Thank you. Attachment 16C2 PROFESSIONAL SERVICES AGREEMENT Contract # 21-7904 for CEI Services for Construction Services for Hamilton Avenue THIS AGREEMENT is made and entered into this day of , 20 21 by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and JOHNSON ENGINEERING, INC. authorized to do business in the State of Florida, whose business address is 2122 Johnson Street, Fort Myers, Florida 33901 (hereinafter referred to as the "CONSULTANT" and/or "CONTRACTOR"). WITNESSETH: WHEREAS, the COUNTY desires to obtain the professional services of the CONSULTANT concerning CEI services for Construction Services for Hamilton Avenue (hereinafter referred to as the "Project"), said services in accordance with the provisions of Section 287.055, Florida Statutes being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and; WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows: ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to COUNTY professional services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the COUNTY for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. Page 1 or 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to the COUNTY. 1.5. CONSULTANT designates Joshua Hildebrand, PE a qualified licensed professional to serve as the CONSULTANT's project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without the COUNTY's prior written approval, and if so removed must be immediately replaced with a person acceptable to the COUNTY. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from the COUNTY to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to the COUNTY. 1.7. The CONSULTANT represents to the COUNTY that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the COUNTY's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Page 2 of 32 PSA_CCNA Single Project Agreement_Ver.4 (13 16C2 Division of Communications, Government and Public Affairs 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8999 Email: PublicRecordRequestPcolliercountyfl.gov The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 1.8. In the event of any conflicts in these requirements, the CONSULTANT shall notify the COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY regarding resolution of each such conflict. The COUNTYS approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project. 1.9. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to CONSULTANT's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY Page 3 of 32 PSA_CCNA Single Project Agreement_Ver.4 1 6 C reserves the right to make sole determination regarding deductions. After notification of deficiency, if the CONSULANT fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge the CONSULTANT for services and/or items necessary to correct the deficiencies directly related to the CONSULTANT's non-performance whether or not the COUNTY obtained substitute performance. 1.10. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without the COUNTY's prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt written notice of any such subpoenas. 1.11. As directed by the COUNTY, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real- Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have common naming conventions (i.e. right-of-way- ROW, centerlines-CL, edge-of-pavement- EOP, etc.), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT 2.1. If authorized in writing by the COUNTY through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in the COUNTY's Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by the COUNTY as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. The COUNTY will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If the COUNTY determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to the COUNTY of the emergency within forty- eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT's right it otherwise may have had to seek an adjustment to its compensation or time of performance under Page 4 of 32 PSA_CCNA Single Project Agreement_Ver.4 DA0 16C2 this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: 2.1.1 Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.1.2 Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, the COUNTY's schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by the COUNTY when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT's control and fault. 2.1.3 Providing renderings or models for the COUNTY's use. 2.1.4 Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting the COUNTY in obtaining such process licensing. 2.1.5 Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.1.6 Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by the COUNTY, other than visits to the Project site or the COUNTY's office. 2.1.7 Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2.1.8 Preparing to serve or serving as a CONSULTANT or witness for the COUNTY in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as part of the Basic Services to be provided herein). 2.1.9 Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice. ARTICLE THREE THE COUNTY'S RESPONSIBILITIES 3.1. The COUNTY shall designate in writing a project manager to act as the COUNTY's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define the COUNTY's policies and decisions with respect to CONSULTANT's services for the Project. However, the Project Manager is not Page 5of32 PSA_CCNA Single Project Agreement_Ver.4 CA 16C2 authorized to issue any verbal or written orders or instructions to the CONSULTANT that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: a. The scope of services to be provided and performed by the CONSULTANT hereunder; b. The time the CONSULTANT is obligated to commence and complete all such services; or c. The amount of compensation the COUNTY is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: a. Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; b. Provide all criteria and information requested by CONSULTANT as to the COUNTY 's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; c. Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT's disposal all available information in the COUNTY's possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; d. Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the COUNTY with respect to the services to be rendered by CONSULTANT hereunder. ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from the COUNTY for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT's services from any cause whatsoever, including those for which the Page 6 of 32 PSA_CCNA Single Project Agreement_Ver.4 MCA( 16C2 COUNTY may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from the COUNTY. CONSULTANT's sole remedy against the COUNTY will be the right to seek an extension of time to its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT's compensation shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the COUNTY's satisfaction that the CONSULTANT's performance is or will shortly be back on schedule. 4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by the COUNTY to CONSULTANT be deemed a waiver of any right or claim the COUNTY may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the COUNTY for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction of the COUNTY's Project Manager before payment for the fixed price contract is authorized. Time and Materials: The COUNTY agrees to pay the contractor for the amount of labor time spent by the CONSULTANT 's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's mark-up). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. Page 7 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above. n Grant--Faded: The hourly rates ass dine B, which is attached hereto, are for aejeney, ARTICLE SIX THE OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by the COUNTY, CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement("Project Documents"). The COUNTY shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to the COUNTY the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring the COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use on this Project. CONSULTANT warrants to the COUNTY that it has full right and authority to grant this license to the COUNTY. Further, CONSULTANT consents to the COUNTY's use of the Project Documents to complete the Project following CONSULTANT's termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges the COUNTY may be making Project Documents available for review and information to various third parties and hereby consents to such use by the COUNTY. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder. The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and hold harmless the COUNTY, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of Page 8 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph 8.1. 8.2. To the extent that the Agreement that the work pertains to a "Professional Services Contract" as defined in Section 725.08(3), Florida Statutes, and the CONSULTANT is a "Design Professional" as defined in Section 725.08(4), Florida Statutes, the indemnification provided herein shall be limited as provided in Sections 725.08(1) & (2), Florida Statutes. ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2. All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3. All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests' provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against the COUNTY for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by the COUNTY applicable to this Project. 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. 9.4. CONSULTANT, its subconsultants and the COUNTY shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by the COUNTY, except such rights as they may have to the proceeds of such insurance held by any of them. Page 9 of 32 PSA_CCNA Single Project Agreement_Ver.4 CA 16C2 9.5. All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements: 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff, unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this Agreement shall, however, be construed as constituting an agreement between the COUNTY and any such other person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third party any claim or right of action against the COUNTY beyond such as may then otherwise exist without regard to this Agreement. 10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. All personnel, identified in Schedule F shall not be removed or replaced without the COUNTY's prior written consent. 10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the COUNTY. Each subconsultant or subcontract agreement shall preserve and protect the rights of the COUNTY under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the sub consulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub- subconsultants or sub-subcontractors. 10.4. CONSULTANT acknowledges and agrees that the COUNTY is a third-party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between the COUNTY and any subconsultant or subcontractor. Further, all such contracts shall provide that, at the COUNTY's discretion, they are assignable to the COUNTY upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS Page 10 of 32 PSA_CCNA Single Project Agreement_Ver.4 1 61 11.1. CONSULTANT's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the COUNTY arising out of this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANT's services nor payment by the COUNTY shall be deemed to be a waiver of any of the COUNTY's rights against CONSULTANT. ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for the COUNTY to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT's failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT's failure to properly and timely perform the services to be provided hereunder or as directed by the COUNTY, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT's principals, officers or directors, or (d) CONSULTANT's failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT's failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The COUNTY may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below. 12.3. The COUNTY shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such termination for convenience, CONSULTANT'S recovery against the COUNTY shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against the COUNTY, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. 12.4. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the COUNTY all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Article 6, that are in CONSULTANT's possession or under its control. 12.5. The COUNTY shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior Page 11 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 12.6. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) the COUNTY otherwise persistently fails to fulfill some material obligation owed by the COUNTY to CONSULTANT under this Agreement, and (ii) the COUNTY has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving THE COUNTY a second fourteen (14) days written notice of CONSULTANT's intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to the COUNTY of CONSULTANT's intent to terminate this Agreement. If the COUNTY does not cure its default within fourteen (14) days after receipt of CONSULTANT's written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the COUNTY, terminate the Agreement and recover from the COUNTY payment for Services performed through the termination date, but in no event, shall CONSULTANT be entitled to payment for Services not performed or any other damages from the COUNTY. ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. 13.2. In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs supporting the compensation for CONSULTANT's services to be provided under this Agreement are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees that the original Agreement price and any additions thereto shall be adjusted to exclude any significant sums by which the COUNTY determines the Agreement price was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit costs. All such adjustments shall be made within one (1) year following the end of this Agreement. ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services Page 12 of 32 PSA_CCNA Single Project Agreement_Ver.4 cp'O 16C2 • required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following the COUNTY's address of record: Board of County Commissioners for Collier County, Florida Division Name: Facilities Management Division Division Director: Ed Finn Address: 3335 Tamiami Trail E. Naples, FL 34112 Administrative Agent/PM: Olivier Sureau Telephone: 239-252-8380 E-Mail(s): Olivier.Sureau@Colliercountyfl.gov 16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT's address of record: Company Name: Johnson Engineering, Inc. Address: 2122 Johnson Street Fort Myers, Florida 33901 Attention Name & Title: Lonnie V. Howard, P.E., President; Joshua Hildebrand, P.E. Telephone: 239-872-4039 E-Mail(s): Ivh@johnsoneng.com;jjh@johnsoneng.com 16.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. Page 13 of 32 PSA_CCNA Single Project Agreement_Ver.4 Cno 16C2 ARTICLE SEVENTEEN MISCELLANEOUS 17.1. CONSULTANT, in representing the COUNTY, shall promote the best interests of the COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair dealing. 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of the COUNTY. 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 17.8. This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 17.9. The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE Schedule E CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE Schedule F KEY PERSONNEL Schedule G Other: Solicitation # 21-7904 , including all Attachment(s), Exhibit(s) &Addendum Consultant's Proposal • 17.10. pl Page 14 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 the Contract Documents upon the CONSULTANT at the COUNTY's discretion. ARTICLE EIGHTEEN APPLICABLE LAW 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE NINETEEN SECURING AGREEMENT/PUBLIC ENTITY CRIMES 19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. At the time this Agreement is executed, CONSULTANT shall sign and deliver to the COUNTY the Truth-In-Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E. CONSULTANT's compensation shall be adjusted to exclude any sums by which the COUNTY determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." Page 15 of 32 PSA_CCNA Single Project Agreement_Ver.4 i 6 C ) ARTICLE TWENTY DISPUTE RESOLUTION 20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached during negotiations to the COUNTY for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached at mediation to the COUNTY's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. ARTICLE TWENTY-ONE IMMIGRATION LAW COMPLIANCE 21.1. By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the COUNTY shall have the discretion to unilaterally terminate this Agreement immediately. Page 16 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement the day and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS FOR COLLIER COUNTY, FLORIDA Crystal K. Kinzel;.Clerk of Courts & Comptroller • By: I v�v i By: 41"1- D4 • b NMI Tsa l�^ , Chairman Atlas as to Chai man . ) 'signatwe only. Approved as to Form a d Legality: �(,( PtscsiS oun y Attorney NW) AA • 6r ,le Name Consultant: Consultant's Witnesses: JOHNSON ENGINEERING, INC. By: // Witness Lonnie V. Howard, President M►chzlk CokirarGS, Aamr Arcl vc Name and Title A6siYce-e k Name and Title des �c Pe(e2, ^'��^'�a r Name and Title Page 17 of 32 PSA_CCNA Single Project Agreement_Ver.4 CM)) 16C2 SCHEDULE A STATEMENT OF WORK ❑■ following this page (pages through10 ) Page 18 of 32 PSA_CCNA Single Project Agreement_Ver.4 I6C2 SCHEDULE "A" STATEMENT OF WORK CEI SERVICES FOR CONSTRUCTION SERVICES FOR HAMILTON AVENUE SCOPE OF WORK This scope of services describes and defines the Construction Engineering and Inspection(CEI)services which are required for constructability review,value engineering,contract administration,inspection,and materials sampling and testing for the construction project listed below. SCOPE The project for which the services are required are: County Project No:83011 cons Descriptions: Roadway Improvement Construction will be according to Improvements of Hamilton Ave documents prepared by RWA Engineering,Inc.and other design subconsultants to RWA. County:Collier Exercise independent professional judgment in performing obligations and responsibilities under this Agreement.Pursuant to Section 4.1.4 of the Construction Project Administration Manual(CPAM),the authority of the Consultant's lead person,such as theSenior Project Engineer, and the Consultant's Project Administrator shall be identical to the Collier County Construction Management Department. Services provided by the Consultant shall comply with FDOT manuals and all applicable Collier County manuals,standards,procedures, and memorandums in effect as of the date of execution of the agreement unless otherwise directed in writing by the County. Such FDOT manuals,procedures,and memorandums are found at the State Construction Office's website,see link below https://www.fdot.gov/design/standardplans/default.shtm. On a single Construction Contract,it is a conflict of interest for a professional firm to receive compensation from both the County and the Contractor either directly or indirectly. LENGTH OF SERVICE CEI contract may begin 3 weeks prior to the construction contract NTP and will end two months after construction completion. The services for each Construction Contract shall begin upon written notification to proceed by the County.The County Construction Project Manager shall track the execution of the Construction Contract such that the Consultant is given timely authorization to begin work. While no personnel shall be assigned until written notification by the County has been issued, the Consultant shall be ready to assign personnel within two weeks of notification.For the duration of the project,coordinate closely with the County and Contractor to minimize rescheduling of Consultant activities due to construction delays or changes in scheduling of Contractor activities. Page 1of10 16C2 DEFINITIONS A. Agreement: The Professional Services Agreement between the County and the Consultant setting forth the obligations of the parties thereto,including but not limited to the performance of the work,furnishing of services,and the basis of payment. B. Contractor:The individual,firm,or company contracting with the County for performance of work or furnishing of materials. C. Construction Contract:The written agreement between the County and the Contractor setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of labor and materials,and the basis of payment. D. Construction Project Manager: The County employee assigned to manage the Construction Engineering and Inspection Contract and represent the County during the performance of the services covered under this agreement. E. Construction Training/Qualification Program(CTQP):The Department program for training and qualifying technicians in Aggregates,Asphalt,Concrete,Earthwork,and Final Estimates Administration.Program information is available at CTQP website. F. Consultant: The Consulting firm under contract to the County for administration of Construction Engineering andlnspection services. G. Consultant Project Administrator: The employee assigned by the Consultant to be in charge of providing Construction Contract administration services for one or more Construction Projects. H. Consultant Senior Project Engineer:The Engineer assigned by the Consultant to be in charge of providing Construction Contract administration for one or more Construction Projects.This person may supervise other Consultant employees and act as the lead Engineer for the Consultant. I. County Construction Manager:The administrative head of the Facilities Management Division J. Director of Transportation Operations: The Director of Construction, Maintenance, Traffic Operations,Materials,and Safety. K. Division Administrator: The Administrative Head of the County's Growth Management Division/PSD/PUD. L. Engineer of Record:The Engineer noted on the Construction plans as the responsible person for the design andpreparation of the plans. M. FDOT Operations Engineer: The Engineer assigned to a particular County or area to administer Construction andMaintenance Contracts for the FDOT. N. Public Information Officer: The County employee assigned to manage the Public Information Program. O. Resident Compliance Specialist:The employee assigned by the Consultant to oversee project specific compliancefunctions. P. Resident Engineer: The Engineer assigned to a particular County or area to administer Construction Contracts forthe Department. Q. Owner: The Board of County Commissioners for Collier County. Florida. A political subdivision of the State ofFlorida. R. County:Collier County,a political subdivision of the State of Florida. ITEMS TO BE FURNISHED BY THE COUNTY TO THE CONSULTANT A. The County, on an as needed basis, will furnish the following Construction Contract documents for this project.These documents may be provided in either paper or electronic format. 1. Construction Plans,electronic copy and 1 hard copy sets in size 11"x 17" 2. Specification Package, 1 hard copy sets in size 8-1/2"x 11" 3. Copy of the Executed Construction Contract, 1 hard copy and 4. Utility Agency's Approved Material List(if applicable). 5. Executed Utility Work Schedules(if applicable) Page 2 of 10 C 16C2 ITEMS FURNISHED BY THE CONSULTANT FDOT DOCUMENTS All applicable FDOT documents referenced herein shall be a condition of this agreement.All FDOT documents, directives, procedures, and standard forms are available through the FDOT's Internet website. Most items can be purchased through the following address.All others can be acquired through the District Office or on-line at the Department's website. Florida Department of Transportation Maps and Publication Sales 605 Suwannee Street,MS 12 Tallahassee,Florida 32399-0450 Telephone No.(850)488-9220 http://www.dotstate.fl.us/construction/ OFFICE AUTOMATION Provide all software and hardware necessary to carry out the responsibilities efficiently and effectively under this agreement. Provide each inspection staff with a laptop computer capable of running PROCORE software needed for project scheduling,documentation,connection using a mobile broadband connection at the jobsite.All computer coding shall be input by Consultant personnel using equipment furnished by them.PROCORE license to be furnished by the County and/or Contractor. Ownership and possession of computer equipment and related software, which is provided by the Consultant, shall remain at all times with the Consultant.The Consultant shall retain responsibility for risk of loss or damage to said equipment during performance of this agreement. Field office equipment should be maintained and operational at all times. Current technical specifications for office automation can be viewed at: http://www.dot.state.fl.us/Construction/DesignBuild/Con sultantCEl/Oft i ceAutomation.shtm VEHICLES Vehicles will be equipped with appropriate safety equipment and must be able to effectively carry out requirements of this agreement. Vehicles shall have the name of the consulting firm visibly displayed on both sides of the vehicle. FIELD EQUIPMENT Supply survey, inspection, and testing equipment essential to perform services under this agreement; such equipment includes non-consumable and non-expendable items.Hard hats shall have the name of the consulting firm visibly displayed.Equipment described herein and expendable materials under this agreement will remain the property of the Consultant and shall be removed at completion of the work. Handling of nuclear density gauges shall be in compliance with their license. Retain responsibility for risk of loss or damage to said equipment during performance of this agreement. Field office equipment shall be maintained and in operational condition at all times. LICENSING FOR EQUIPMENT OPERATIONS Obtain proper licenses for equipment and personnel operating equipment when licenses are required.The license and supportingdocuments shall be available for verification by the County,upon request. Radioactive Materials License for use of Surface Moisture Density Gauges shall be obtained through the State of Florida Department of Health. LIAISON RESPONSIBILITY OF THE CONSULTANT For the duration of the agreement,consultant must keep the County's Construction Project Manager informed of Page 3 of 10 16C2 all significant activities, decisions, correspondence, reports, and other communications related to its responsibilities under this agreement. Facilitate communications between all parties (i.e. architectural, mechanical, materials, landscaping, local agencies, etc.) ensuring responses and resolutions are provided in a timely manner. Maintain accurate records to document the communication process. Submit all administrative items relating to Invoice Approval,Personnel Approval,User IDs,Time Extensions, change orders and Supplemental Amendments to the Construction Project Manager for review and approval. PERFORMANCE OF THE CONSULTANT During the term of this agreement and all Supplemental Amendments thereof,the County will review various phases of Consultant operations, such as construction inspection, materials sampling and testing, and administrative activities, to determine compliance with this agreement. If deficiencies are indicated, remedial action shall be implemented immediately.County recommendations andConsultant responses/actions are to be properly documented by the Consultant.No additional compensation shall be allowed for remedial action taken by the Consultant to correct deficiencies.Remedial actions and required response times may include but are not necessarily limited to the following: A. Further subdivide assigned inspection responsibilities, reassign inspection personnel, or assign additional inspectionpersonnel,within one week of notification. B. Immediately replace personnel whose performance has been determined by the Consultant and/or the County to beinadequate. C. Immediately increase the frequency of monitoring and inspection activities in phases of work that are the Consultant'sresponsibility. D. Increase the scope and frequency of training of the Consultant personnel. Hamilton Avenue CEI Services will include the following tasks: Task 1.1 Hamilton Avenue Roadway Construction Observation and Inspection Task 1.2 Hamilton Avenue Material Laboratory Testing and Other Miscellaneous Testing Task 2.1 Hamilton Avenue Landscaping Construction Observation Support Services TASK DESCRIPTION TASK 1.1 HAMILTON AVENUE ROADWAY CONSTRUCTION OBSERVATION AND INSPECTION REQUIREMENTS OF THE CONSULTANT GENERAL It shall be the responsibility of the Consultant to administer,monitor,and inspect the Construction Contract such that the project is constructed in reasonable conformity with the plans,specifications,and special provisions for the Construction Contract. Observe the Contractor's work to determine the progress and quality of work. Identify discrepancies, report significant discrepancies to the County, and notify the Contractor of such observed discrepancies. Consult with the Construction Project Manager as necessary and direct all issues, which exceed delegated authority to the Construction Project Manager for action or direction.Inform the Construction Project Manager of any significant omissions,substitutions,defects,and deficiencies noted in the work of the Contractor and the corrective action that has been directed to be performed by the Contractor. SURVEY CONTROL Check the survey control baseline(s)along with sufficient baseline control points and bench marks at as needed or at the request of the County Project Manager. ON-SITE INSPECTION Page 4 of 10 S 16C2 Monitor the Contractor's on-site construction activities and inspect materials entering into the work in accordance with the plans, specifications, and special provisions for the Construction Contract to determine that the projects are constructed in reasonable conformity with such documents. Maintain detailed accurate records of the Contractor's.daily operations and of significant events that affect the work. Monitoring and inspection of off-site activities and fabrication is not required unless otherwise stipulated by this agreement. Monitor and inspect Contractor's Work Zone Traffic Control Plan and review modifications to the Work Zone Traffic Control Plan, including Alternate Work Zone Traffic Control Plan, in accordance with the FDOT's procedures. Consultant employees performingsuch services shall be qualified in accordance with the FDOT's guidelines of Traffic Training (Topic No.625-010-010-a). CONSTRUCTION ENGINEERING AND INSPECTION(CEI) The consultant shall provide onsite inspection services during construction as necessary to determine if the Contractor is in general compliance with the construction documents and applicable specifications. Such visits and observations by the consultant are not intended to be exhaustive or to extend to every aspect of the work in progress,or to involve detailed inspections of the work beyondthe responsibilities specifically assigned to the consultant in the resultant contract. The consultant shall keep the County informed of the progress of such inspections and results. The consultant shall not,during such visits or as a result of such observations of the contractor's work in progress, supervise, direct or have control over the contractor's work nor shall the consultant have authority over or responsibility for the means, methods, techniques, sequences or procedures of construction selected by the contractor,for safety precautions and programs incident to the work of the contractor or for any failure of the contractor to comply with laws, rules, regulations, ordinances, codes or orders applicable to the contractor's furnishing and performing the work. Accordingly, the consultant neither guarantees the performance of any contractor nor assumes responsibility for any contractor's failure to furnish and perform its work in accordance with the construction documents. Services shall include maintaining the required level of surveillance of Contractor activities,interpreting plans, specifications,and special provisions for the Construction Contract.Maintain complete,accurate records of all activities and events relating to the project and properly document all project changes.The following services shall be performed: (1) Attend a pre-service meeting for the agreement within ten(10)business days after the Notice-to- Proceed.At the pre-service meeting the CONSULTANT shall submit action request packages for personnel approval for immediate staff needs and a copy/ computer file of the final negotiated staffing.The CONSULTANT shall record a complete and concise record of the proceedings of the meeting and distribute copies of these minutes to the participants and other interested parties within seven(7)days of the meeting date. (2) Schedule and conduct a pre-construction conference in accordance with Article 8-3.5 of the FDOT Standard Specification for Road and Bridge Construction. The purpose of these meetings is to discuss the required documentation, including as-builts, necessary for permit(s) compliance. Record significant information revealed and decisions made at this conference and distribute copies of these minutes to the appropriate parties.The meeting shall also be electronically recorded,and the CONSULTANT shall maintain all tapes of the meeting for the duration of the Contract. (3) Consultant should organize and conduct bi-weekly progress meetings, set the agenda,record and provide minutes.The Consultant shall make use of the existing construction management software (Procore)and input updates to the same for this project. (4) Verify that the Contractor is conducting inspections, preparing reports and monitoring all storm water pollution prevention measures associated with the project.For each project that requires the use of the NPDES General Permit,provide at least one inspector who has successfully completed Page 5of10 16C2 the "Florida Stormwater,Erosion,and Sedimentation Control Training and Certification Program for Inspectors and Contractors".The Consultant's inspector will be familiar with the requirements set forth in the FEDERAL REGISTER,Vol.57,No. 187,Friday,September 5, 1992,pages 4412 to 4435 "Final NPDES General Permits for Storm Water Discharges from Construction Sites"and the Department's guidelines.Coordinate with the Contractors Public Information Officer to assure updated information and MOT issues are communicated to the public. (5) Analyze the Contractor's schedule(s) (i.e. baseline(s), revised baseline(s), updates, as-built, etc.) for compliance with the contract documents.Elements including,but not limited to,completeness, logic,durations,activity,flow,milestone dates,concurrency,resource allotment,and delays will be reviewed. Verify the schedule conforms with theconstruction phasing and MOT sequences, including all contract modifications. Provide a written review of the schedule identifying significant omissions,improbable or unreasonable activity durations,errors in logic,and any other concerns as detailed in CPAM. (6) Analyze problems that arise on a project and proposals submitted by the Contractor; work to resolve such issues and process the necessary paperwork. (7) Facilitate coordination and communication between Utility Agency's representatives,Department's staff and Contractors executing the work. Identify potential utility conflicts and assist in the resolution of utility issues including Department and Local Government owned facilities.Note any visible damage to private or public utilities as a result of the contractors work and assist in coordinating the appropriate resolution. Consultant shall inspect and document any minor adjustments/repairs to County owned utilities as needed to resolve isolated conflicts. Identify, review, and track progress of Joint Project Agreements, and/or other Department and utility agreements.Address work progress,track reimbursement activities,and address betterment and salvage determination. Prepare all necessary documentation to support reimbursement activities and betterment and salvage determination. (8) Produce reports,verify quantity calculations and field measure for payment purposes as needed to prevent delays in Contractor operations and to facilitate prompt processing of such information in order for the Department to make timely payment to the Contractor. (9) Prepare and make presentations for meetings and hearings before the Dispute Review Boards in connection with the project covered by this agreement. (10)Monitor each Contractor and Subcontractor's compliance with specifications and special provisions of the Construction Contract in regard to payment of predetermined wage rates in accordance with FDOT procedures. (11)Prepare and submit to the Construction Project Manager monthly,a Construction Status Reporting System(CSRS)report,in a format to be provided by the County. (12)Video tape the pre-construction conditions throughout the project limits. Provide a digital photo log or video of project activities,with heavy emphasis on potential claim items/issues and on areas of real/potential public controversy. (13)Provide a digital camera for photographic documentation of pre-construction state and of noteworthy incidents or events during construction. Photos should be provided monthly to show progress. These photographs will be filed and maintained on the Consultant's computer using a Digital Photo Management system. Photographs shall be taken the day prior to the start of construction and continue as needed throughout the project. Photographs shall be taken the days of conditional,partial and final acceptance. Page 6 of 10 16C2 GENERAL REQUIREMENTS Provide qualified personnel necessary to efficiently and effectively carry out its responsibilities under this agreement. PERSONNEL QUALIFICATIONS Provide competent personnel qualified by experience and education. Submit in writing to the Construction Project Manager the names of personnel proposed for assignment to the project, including a detailed resume for each containing at a minimum:salary,education,and experience.The Consultant Action Request form for personnel approval shall be submitted to the Construction Project Manager at least two weeks prior to the date an individual is to report to work. Before the project begins, all project staff shall have a working knowledge of the current CPAM and must possess all the necessaryqualifications/certifications for fulfilling the duties of the position they hold. Cross training of the Consultant's project staff is highly recommended to achieve a knowledgeable and versatile project inspection team but shall not be at any additional cost to theCounty and should occur as workload permits.Visit the training page on the State Construction Office website for training dates. Minimum qualifications for the Consultant personnel are set forth as follows.Exceptions to these minimum qualifications will be considered on an individual basis.However,a Project Administrator working under the supervision and direction of a Senior Project Engineer or an Inspector working under the supervision and direction of a Senior Inspector shall have six months from the date of hire to obtain the necessary qualifications/certifications provided all other requirements for such positions are met and the Consultant submits a training plan detailing when such qualifications/certifications and other training relative to the FDOT's procedures, Specifications and Design Standards will be obtained.The County Construction Manager or designee will have the final approval authority on such exceptions. The Senior Project Engineer assigned to the project must have prior experience in roundabout construction and must have advancedMOT certification(10.1 Certification with DOT). STAFFING Once authorized, the Consultant shall establish and maintain appropriate staffing throughout the duration of construction and completion of the final estimate. Responsible personnel,thoroughly familiar with all aspects of construction and final measurements of the various pay items, shall be available to resolve disputed final pay quantities until the County has received a regular acceptance letter.Construction engineering and inspection forces will be required of the Consultant while the Contractor is working. If Contractor operations are substantially reduced or suspended,the Consultant will reduce its staff appropriately. In the event that the suspension of Contractor operations requires the removal of Consultant forces from the project, the Consultant will be allowed ten(10)days maximum to demobilize,relocate,or terminate such forces. QUALITY ASSURANCE(QA)PROGRAM QUALITY ASSURANCE PLAN Within thirty (30)days after receiving award of an agreement, furnish a QA Plan to the Construction Project Manager. The QA Plan shall detail the procedures, evaluation criteria, and instructions of the Consultant's organization for providing services pursuant to this agreement. Unless specifically waived,no payment shall be made until the County approves the Consultant QA Plan. Significant changes to the work requirements may require the Consultant to revise the QA Plan. It shall be the responsibility of the Consultant to keep the plan current with the work requirements.The Plan shall include,but not be limited to,the following areas: Organization A description is required of the Consultant QA Organization and its functional relationship to the part of the organization performing the work under the agreement.The authority,responsibilities and autonomy of the QA organization shall be detailed as well as the names and qualifications of personnel in the quality control organization. Quality Assurance Reviews Page 7 of 10 C 16C2 Detail the methods used to monitor and achieve organization compliance with agreement requirements for services and products. Quality Assurance Records Outline the types of records which will be generated and maintained during the execution of the QA program. Control of Subconsultants and Vendors Detail the methods used to control subconsultant and vendor quality. Quality Assurance Certification An officer of the Consultant firm shall certify that the inspection and documentation was done in accordance with FDOT specifications,plans,standard indexes,and Department procedures. QUALITY ASSURANCE REVIEWS The CCEI shall perform an initial QA review within the first month of the start of construction. QUALITY RECORDS Maintain adequate records of the quality assurance actions performed by the organization (including subcontractors and vendors)inproviding services and products under this agreement.All records shall indicate the nature and number of observations made, the number and type of deficiencies found, and the corrective actions taken. All records shall be available to the Department, upon request, during the agreement term. All records shall be kept at the primary job site and shall be subject to audit review. CERTIFICATION OF FINAL ESTIMATES FINAL ESTIMATE AND AS-BUILT PLANS SUBMITTAL Prepare documentation and records in compliance with the agreement,Statewide Quality Control(QC)Plan, or Consultant's approved QC Plan and the FDOT's Procedures as required by Section 4.1.4 of Review and Administration Manual. Submit the Final Estimate(s) and one(1) set of final "as-built plans" documenting the Contractor's work in accordance with the Review and Administration Manual. The as-built plans are to be supplied by the Contractor and reviewed by the Consultant prior to submission to the County. Revisions to the Certified Final Estimate will be made at no additional cost to the Department. CERTIFICATION Consultant personnel preparing the Certified Final Estimate Package shall be CTQP Final Estimates Level II. Duly authorized representative of the Consultant firm will provide a notarized certification on a form pursuant to FDOT's procedures. The County's Project Administrator/Manager shall be responsible for verifying and maintaining copies of all required licenses, certifications, and qualifications requested from the Consultant throughout the term of the contract. OFFER OF FINAL PAYMENT Prepare the Offer of Final Payment package as outlined in Chapter 14 of the Review and Administration Manual. The package shall accompany the Certified Final Estimates Package submitted to the Construction Project Manager for review.The Consultant shall be responsible for forwarding the Offer of Final Payment Package to the Contractor. AGREEMENT MANAGEMENT GENERAL With each monthly invoice submittal,the Consultant will provide a status report for the agreement.This report will provide an accounting of the additional agreement calendar days allowed to date, an estimate of the additional calendar days anticipated to be added to the original schedule time, an estimate of the agreement completion date, and an estimate of the Consultant funds expiration date per the agreement schedule for the prime Consultant and for each subconsultant.The Consultant will provide a printout from the Equal Opportunity Page 8of10 16C ? Reporting System showing the previous month's payments made to subconsultants. Invoices not including this required information may be rejected. When the Consultant identifies a condition that will require an amendment to the agreement,the Consultant will communicate this need to the Construction Project Manager for acceptance. Upon acceptance, prepare and submit an Amendment Request(AR),and all accompanying documentation to the Construction Project Manager for approval and further processing. The AR is to be submitted at such time to allow the County 12 weeks to process,approve,and execute the AR.The content and format of the AR and accompanying documentation shall be in accordance with the instructions and format to be provided by the County. The Consultant is responsible for performing follow-up activities to determine the status of each Amendment Request submitted to the County. TASK 1.2 HAMILTON AVENUE MATERIAL LABORATORY TESTING AND OTHER MISCELLANEOUS TESTING SAMPLING AND TESTING Perform sampling and testing in conjunction with an independent, licensed laboratory, whose selection has been approved in writing by the Construction Project Manager,hired by the Consultant,sampling and testing of component materials and completed work items so that the materials and workmanship incorporated in the project are in reasonable conformity with the plans, specifications and contract provisions. The minimum sampling frequencies set out in the FDOT's Materials Sampling,Testing and Reporting Guide shall be met.In complying with the aforementioned guide, provide daily surveillance of the Contractor's Quality Control activities and perform the sampling and testing of materials and completed work items for verification and acceptance. Sampling of materials and components at locations remote from the project site will not be required with the exception of asphalt plant inspection and perform testing of materials normally done in a laboratory remote from the project site. Determine the acceptability of all materialsand completed work items on the basis of either test results or verification of a certification, certified mill analysis, DOT label,DOT stamp,etc.The County will monitor the effectiveness of the Consultant's testing procedures through observation and independent assurance testing. Sampling, testing and laboratory methods shall be as required by the FDOT's Standard Specifications, Supplemental Specifications or as modified by the Special Provisions of the Construction Contract. Documentation reports on sampling and testing performed by the Consultant shall be submitted during the same week that the construction work is done. Transport laboratory samples to the appropriate laboratory.The Consultant shall provide daily surveillance of the Contractor's Quality Control activities at the project site in regard to concrete and perform acceptance sampling at the specified frequency. Supply CTQP (Construction Training Qualification Program) qualified technicians for concrete inspection.Supply CTQP qualified Asphalt Paving and Plant Technicians for asphalt inspection. Supply CTQP qualified Earthwork Construction Inspection Technicians for embankment,pipe backfill,subgrade,base and asphalt inspection. TASK 2.0 HAMILTON AVENUE OTHER SERVICES OTHER SERVICES Upon written authorization by the Construction Project Manager,the Consultant will perform additional services in connection withthe project not otherwise identified in this agreement.The following items may be required by the County to supplement the Consultant services under this agreement. Page 9 of 10 16CZ A. Assist in the timely preparation of all claims and necessary rebuttals with the organization of all supporting documentation as needed or required by Collier County pursuant to the Collier County Alternative Dispute Resolution Procedures. B. Provide qualified engineering witnesses and exhibits for any litigation or hearings in connection with the Contract. C. Assist the County Attorney or his designee as directed in the preparation for Binding Arbitration and Pre-Suit Mediation. D. Provide on-and off-site inspection services in addition to those provided for in this agreement. CONTRADICTIONS In the event of a contradiction between the provisions of this Scope of Services and the Consultant's proposal as made a part of their agreement,the provisions of the scope of services shall apply. COUNTY AUTHORITY The County shall be the final authority in considering modifications to the Construction Contract for time,money or any other consideration except matters agreed to by the Contractor through contract changes negotiated by the Consultant,as authorized in herein. Current Additional Services are as follows: TASK 2.1 HAMILTON AVENUE LANDSCAPING CONSTRUCTION OBSERVATION SUPPORT SERVICES The Consultant will provide County with a certified landscape architect for construction observation assessment services during construction, as requested by County. Consultant will coordinate with County to obtain project information as necessary for preparing an existing tree assessment or installation of root barriers to comply with the project design and specifications.At the request of the County,the Consultant may attend meetings with County staff to present the existing tree condition findings and recommendations. Documentation of recommendations and construction observations will be provided to County,via email,within twenty-four(24)hours or County requested site visit(s).This scope of services assumes approximately five (5)eight(8)hour work days of certified arborist or landscape architect support. Page 10 of 10 16 Ct SCHEDULE B BASIS OF COMPENSATION 1. MONTHLY STATUS REPORTS B.1.1. As a condition precedent to payment, CONSULTANT shall submit to the COUNTY as part of its monthly invoice a progress report reflecting the Project status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1. For the Basic Services provided for in this Agreement, the COUNTY agrees to make the payments to CONSULTANT in accordance with the terms stated below. Payments will be made in accordance with the following Schedule; however, the payment of any particular line item noted below shall not be due until services associated with any such line item have been completed or partially completed to the COUNTY's reasonable satisfaction. Lump sum payments will be made upon the percentage complete. In no event shall such Time and Materials compensation exceed the amounts set forth in the table below. Tasks/Item Description Lump Sum Time and Materials Not-To- Exceed 1.1 Hamilton Avenue Construction Observation and Inspection $ $ 358,043.00 1.2 Hamilton Avenue Material Laboratory Testing and Other Miscellaneous Testing $ $ 27,656.00 2.1 Hamilton Avenue Landscape Support Services(Additional Services) $ $ 4,840.00 $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ Total Lump Sum Fee $ Total Time and Materials Fee $390,539.00 GRAND TOTAL FEE $390,539.00 Page 19 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 B.2.2. ■❑*Time and Material Fees: The fees noted in Section B.2.1. shall constitute the amounts to be paid to CONSULTANT for the performance of the Basic Services. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT's personnel, with respect to this Project, including all indirect payroll related costs and fringe benefits, all in accordance with and not in excess of the rates set forth in the Attachment 1 to this Schedule B. With each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by the COUNTY, regarding CONSULTANT's Direct Labor Costs incurred at the time of billing, to be reviewed and approved by the COUNTY. There shall be no overtime pay without the COUNTY's prior written approval. B.2.2.1. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has completed such task as of that particular monthly billing. B.2.3. ❑* . . Services and Additional Scrvices during the subject billing month. B.2.4. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided and as set forth in the Amendment authorizing such Additional Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provision of Section 3.4.1 below. There shall be no overtime pay on Additional Services without the COUNTY's prior written approval. B.2.5. The compensation provided for under Section B.2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are due and payable. 3. SCHEDULE OF PAYMENTS B.3.1. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by the COUNTY. Page 20 o132 PSA_CCNA Single Project Agreement_Ver.4 1 6 C B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT's letterhead and must include the Purchase Order Number and Project name and shall not be submitted more than one time monthly. B.3.3. Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. B.3.4. Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for this Agreement or Additional Services, CONSULTANT shall be limited to a maximum markup of five percent (5%) on the fees and expenses associated with such subconsultants and subcontractors. B.3.4.1 Reimbursable Expenses must comply with §112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items: B.3.4.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.4.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by the COUNTY. Such expenses, if approved by the COUNTY, may include coach airfare, standard accommodations and meals, all in accordance with §112.061, Fla. Stat. Further, such expenses, if approved by the COUNTY, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.4.1.3. Permit Fees required by the Project. B.3.4.1.4. Expense of overtime work requiring higher than regular rates approved in advance and in writing by the COUNTY. B.3.4.1.5. Expense of models for the County's use. B.3.4.1.6. Other items on request and approved in writing by the COUNTY. B.3.4.1.7. The CONSULTANT shall bear and pay all overhead and other expenses, except for authorized reimbursable expenses, incurred by CONSULTANT in the performance of the Services. Page 21 of 32 PSA_CCNA Single Project Agreement_Ver.4 1C B.3.4.1.8. Records of Reimbursable Expenses shall be kept on a generally recognized accounting basis. B.3.5. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring any reimbursable expenses, and absent such prior approval, no expenses incurred by CONSULTANT will be deemed to be a reimbursable expense. REMAINDER OF PAGE INTENTIONALLY LEFT BLANK Page 22 of 32 PSA_CCNA Single Project Agreement_Ver.4 16C2 SCHEDULE B —ATTACHMENT 1 CONSULTANT'S HOURLY RATE SCHEDULE Title Hourly Rate Principal $238 Senior Project Manager $201 Project Manager $165 Senior Engineer $175 Engineer $136 Senior Inspector $117 Inspector $96 Senior Planner $164 Planner $130 Senior Designer $128 Designer $109 Environmental Specialist $120 Senior Environmental Specialist $156 Scientist/Geologist $115 Marine Biologist/Hydrogeologist $133 Senior Marine Biologist/Hydrogeologist $169 Senior GIS Specialist $149 GIS Specialist $114 Clerical/Administrative $73 Senior Technician $102 Technician $83 Surveyor and Mapper $142 CADD Technician $95 Survey Crew-2 Man $152 Survey Crew-3 Man $185 Survey Crew-4 Man $218 Senior Architect $154 Architect $121 MATERIALS AND LAB TESTING RATES Per Attachment The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added via an Amendment upon mutual agreement in advance and in writing by the parties. , the above hourly rates are for purposes of providing estimate(s), as rcquired by the grantor ageney,. Page 23 of 32 PSA_CCNA Single Project Agreement_Ver.4 1 6 C 2 Lab/Materials Testing Fees/Rates CHEMICAL TESTS pH Water Each $9.00 Sulfate Each $49.00 Chloride Each $49.00 Soil pH Each $49.00 Resistivity Each $55.00 Carbonate Content Each $1.33.00 AGGREGATE TESTS Sieve Analysis of Fine Aggregate Each $70.00 Sieve Analysis of Coarse Aggregate Each $86.00 Fine Aggregate Each $131.00 Coarse Aggregate Each $1.3 I.00 EARTHWORKS Standard or Modified Proctor Each $126.00 Limerock Bearing Ratio (LBR)Tests Each $422.00 Sieve Analysis Each $57.00 Organic Content Each $38.00 Moisture Content Each $1.7.00 Atterberg Limits Each $125.00 Percent Fines Each $39.00 CONCRETE Compressive Strength of Concrete Cylinder Each $19.00 Flexural Strength of Beams(minimum charge of 3 beams per set Each $59.00 delivered) ASPHALT Bitumen Extraction and Aggregate Gradation Each $1.91.00 Density Determination of Cored Specimens (minimum charge of 4 core Each $37.00 per set delivered) It 1 6 C SCHEDULE C PROJECT MILESTONE SCHEDULE Number of Calendar Days Task/Item For Completion of Task Description from Date of Notice to Proceed 1.0 Hamilton Avenue Construction Observation 425 and Inspection 1.2 Hamilton Avenue Material Laboratory 425 Testing and Other Miscellaneous Testing 2.2 Hamilton Avenue Landscape Support 425 Services (Additional Services) Page 24 of 32 PSA_CCNA Single Project Agreement_Ver.4 CAv 1 6 q SCHEDULE D INSURANCE COVERAGE 1. The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the below listed minimum required coverages, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be CONSULTANT's sole responsibility. 2. The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. 3. Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the COUNTY or as specified in this Agreement, whichever is longer. 4. Certificates of insurance acceptable to the COUNTY shall be filed with the COUNTY within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance policies required shall be provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the COUNTY. CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project. 6. The acceptance by the COUNTY of any Certificate of Insurance does not constitute approval or agreement by the COUNTY that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. 7. CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the COUNTY. Page 25 of 32 PSA_CCNA Single Project Agreement_Ver.4 t,Ao 16C2 8. Should at any time the CONSULTANT not maintain the insurance coverages required herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand, the COUNTY has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Agreement. 9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and the COUNTY may terminate the Agreement for cause. 10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY. Required by this Agreement? I■I Yes No Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability - The coverage must include Employers' Liability with a minimum limit of $ 1,000,000 for each accident. The insurance company shall waive all claims rights against the COUNTY and the policy shall be so endorsed. 11. United States Longshoreman's and Harbor Worker's Act coverage shall be maintained where applicable to the completion of the work. Required by this Agreement? Yes I.1 No 12. Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Required by this Agreement? Yes I No 13. COMMERCIAL GENERAL LIABILITY. Required by this Agreement? ■ Yes No A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Page 26 of 32 PSA_CCNA Single Project Agreement_Ver.4 Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the following: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, $2,000,000 aggregate. B. The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. 14. Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. The insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 15. Watercraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in subparagraph (1) above if applicable to the completion of the Services under this Agreement. Required by this Agreement? n Yes • No 16. Aircraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Required by this Agreement? Yes ■ No 17. AUTOMOBILE LIABILITY INSURANCE. Required by this Agreement? Al Yes No Business Auto Liability: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-The ownership. Page 27 of 32 PSA_CCNA Single Project Agreement_Ver.4 CP'0 r 18. TECHNOLOGY ERRORS AND OMISSIONS INSURANCE. Required by this Agreement? Yes • No Technology Errors and Omissions Insurance: Coverage shall have minimum limits of $ Per Occurrence. 19. CYBER INSURANCE. Required by this Agreement? Yes 1111 No Cyber Insurance: Coverage shall have minimum limits of$ Per Occurrence. 20. UMBRELLA LIABILITY. A. Umbrella Liability may be maintained as part of the liability insurance of the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverages required herein and shall include all coverages on a "following form" basis. B. The policy shall contain wording to the effect that, in the event of the exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. 21. PROFESSIONAL LIABILITY INSURANCE. Required by this Agreement? ■ Yes I No A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its legal liability for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under this insurance. Such insurance shall have limits of not less than $ 1,000,000 each claim and aggregate. B. Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT. Deductible amounts are subject to the approval of the COUNTY. C. The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the COUNTY. D. The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to the COUNTY of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer. In the event Page 28 0132 PSA_CCNA Single Project Agreement_Ver.4 ei I6C2 of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by the COUNTY. 22. VALUABLE PAPERS INSURANCE. In the sole discretion of the COUNTY, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. 23. PROJECT PROFESSIONAL LIABILITY. A. If the COUNTY notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with the COUNTY and the COUNTY's insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT's professional liability policy. If no credit is available from CONSULTANT's current professional policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to the COUNTY. Should no credit accrue to the COUNTY, the COUNTY and CONSULTANT, agree to negotiate in good faith a credit on behalf of the COUNTY for the provision of project-specific professional liability insurance policy in consideration for a reduction in CONSULTANT's self-insured retention and the risk of uninsured or underinsured consultants. B. The CONSULTANT agrees to provide the following information when requested by the COUNTY or the COUNTY's Project Manager: 1. The date the professional liability insurance renews. 2. Current policy limits. 3. Current deductibles/self-insured retention. 4. Current underwriter. 5. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. 6. Cost of professional insurance as a percent of revenue. 7. Affirmation that the design firm will complete a timely project errors and omissions application. C. If the COUNTY elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and the COUNTY will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds. END OF SCHEDULE D Page 29 of 32 PSA_CCNA Single Project Agreement_Ver.4 l6C2 SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida Statutes, Johnson Engineering, Inc. (company's name) hereby certifies that wages, rates and other factual unit costs supporting the compensation for the services of the CONSULTANT to be provided under the Professional Services Agreement, concerning "CEI Services for Construction Services for Hamilton Avenue "project" is accurate, complete and current as of the time of contracting. BY• TITLE: Lonnie V.Howard,President DATE: Z i A/o✓ Aga' Page 30 of 32 PSA_CCNA Single Project Agrcement_Ver.4 i I6C2 SCHEDULE F KEY PERSONNEL Name Personnel Category Percentage of Time Ryan Bell,P.E., PTOE Principal 1% Josh Hildebrand,P.E.,PTOE Senior Engineer 12.5% John Glenn, P.E. Senior Engineer 12.5% Roy Godshall Senior Inspector 90% Arnie Fiore Senior Inspector As-Needed Ron Ward Senior Inspector As-Needed Brennan McGill Inspector 10% Kathy Hanigan Clerical/Administrative 12% Jeff Nagle,RLA Architect As-Needed Guy Adam,PLS Surveyor and Mapper As-Needed Page 31 of 32 PSA_CCNA Single Project Agreement_Ver.4 I C ? SCHEDULE G Other: (Description) ❑ following this page (pages through ) ■❑ this schedule is not applicable Page 32 of 32 PSA_CCNA Single Project Agreement_Ver.4 CAO I6C OQuinnPatrick From: GonzalezGreily Sent: Tuesday, November 23, 2021 10:59 AM To: OQuinnPatrick Cc: Contracts;ZimmermanSue; ReynosoAna; MiguelVanessa; AbreuLeisy Subject: RE: COI In Compliance: 21-7904 CEI Services for Construction Services for Hamilton Avenue (Johnson Engineering, Inc.) Patrick, The COI is incompliance.Thank you. Respectfully, Greily Gonzalez, ARM Manager, Risk Finance Co er County Risk Management Division 3311 Tamaimi Trail E, Bldg D, Naples, FL 34112 Ph:239.252.8914 Fax: 239.252.8048 NOTE: Email Address Has Changed MINING COLLIER COUNTY NCE 2011 Take the Risk Management Customer Survey Please use your iPhone to access the below QR Code. Aim at it as if you were taking a picture of it; the Survey link will pop up. Clink on the link to access the survey! ❑f ar +�+�r1 ❑it ° TAKE THE SURVEY From: OQuinnPatrick<Patrick.OQuinn@colliercountyfl.gov> Sent:Tuesday, November 23, 2021 8:54 AM To: GonzalezGreily<Greily.Gonzalez@colliercountyfl.gov> Cc:Contracts<Contracts@colliercountyfl.gov>; ZimmermanSue<Sue.Zimmerman@colliercountyfl.gov>; ReynosoAna <Ana.Reynoso@colliercountyfl.gov>; MiguelVanessa <Vanessa.Miguel@colliercountyfl.gov>; AbreuLeisy 1 16C2 <Leisy.Abreu@colliercountyfl.gov> Subject: COI In Compliance: 21-7904 CEI Services for Construction Services for Hamilton Avenue (Johnson Engineering, Inc.) Dear Greily, Please review the COI provided by the vendor. We need you to confirm if it's in compliance as per our Insurance Request form. Thank you for your time. Respectfully, Patrick O'Quinn Purchasing Technician C.;o kr County PROCUREMENT SERVICES DIVISION 3295 Tamiami Trail East, Bldg. C2 I Naples, FL 34112 Phone I Office (239) 252-8407 Main I (239)252-8407 Patrick.OQuinn(a�colliercountyfl.gov "HOW ARE WE DOING?" Please Take Our Survey We appreciate your feedback! BidSync(now known as Periscope SOURCE) is Collier County's bid platform, and registration is free. Register today at www.bidsync.com. For registration assistance please contact BidSync customer service at 800-990-9339 or email: support cr bidsync.com Under Florida Law, e-mail addresses are public records. If you do not want your e-mail address released in response to a public records request, do not send electronic mail to this entity. Instead, contact this office by telephone or in writing. 2 16C Aco CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) �.� 11/22/2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT BKS Partners NAME: Yaritza Soto P.O. Box 60043 ANC No.Eat):239-931-3021 (A/C,No):239-931-5604 Fort Myers FL 33906-6043 ADDRESS: yaritza.soto@bks-partners.com INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:American Casualty Company of R 20427 INSURED JOHNS05 INSURER B:The Continental Insurance Co 35289 Johnson Engineering, Inc. INSURERC:Valley Forge Insurance Company PO Box 2112p y 20508 Fort Myers FL 33902-2112 INSURER D:Continental Casualty Company 20443 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:867091781 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LTR INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY Y 4027219232 9/15/2021 9/15/2022 EACH OCCURRENCE $1,000,000 CLAIMS-MADE X OCCUR DAMAGE TO RENTED PREMISES(Ea occurrence) $100,000 MED EXP(Any one person) $15,000 X XCU PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY X JEt° X LOC PRODUCTS-COMP/OPAGG $2,000,000 OTHER: $ D AUTOMOBILE LIABILITY Y 5084100207 9/15/2021 9/15/2022 COMBINED SINGLE LIMIT $1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X HIRED X NON-OWNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY (Per accident) X PIP PIP $10,000 B X UMBRELLA LIAB X OCCUR 4034928401 9/15/2021 9/15/2022 EACH OCCURRENCE $5,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $5,000,000 DED X RETENTION$1 n Ann $ C WORKERS COMPENSATION WC434939852 9/24/2021 9/24/2022 X PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBEREXCLUDED? N N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) PROJECT:Contract No.21-7904-CEI Services for Construction Services for Hamilton Avenue Collier County Board of County Commissioners is listed as additional insured with respect to general liability on a primary and noncontributory basis,as per endorsement CNA75079XX and auto liability per CA2048.30 days notice of cancellation applies except 10 days for nonpayment. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Collier County Board of County Commissioners 3295 Tamiami Trail East, Bldg. C-2 Naples FL 34112 AUTHORIZED REPRESENTATIVE 72VLzi ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD CNA Business AL4licy Policy Endorsement DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s) who are "insureds" for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: JOHNSON ENGINEERING, INC. Endorsement Effective Date: 09/15/2021 SCHEDULE Name Of Person(s) Or Organization(s): ANY PERSON OR ORGANIZATION THAT THE NAMED INSURED IS OBLIGATED TO PROVIDE INSURANCE WHERE REQUIRED BY A WRITTEN CONTRACT OR AGREEMENT IS AN INSURED,BUT ONLY WITH RESPECT TO LEGAL RESPONSIBILITY FOR ACTS OR OMISSIONS OF A PERSON/ORGANIZATION FOR WHOM LIABILITY COVERAGE IS AFFORDED UNDER THIS POLICY Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Each person or organization shown in the Schedule is an "insured" for Covered Autos Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Paragraph A.1. of Section II - Covered Autos Liability Coverage in the Business Auto and Motor Carrier Coverage Forms and Paragraph D.2. of Section I - Covered Autos Coverages of the Auto Dealers Coverage Form. Form No: CA 20 48 10 13 Policy No:BUA 5084100207 Endorsement Effective Date: Endorsement Expiration Date: Policy Effective Date: 09/15/2021 Endorsement No: 6; Page: 1 of 1 Policy Page: 75 of 290 Underwriting Company: Continental Casualty Company, 151 N Franklin St, Chicago, IL 60606 ©Copyright Insurance Services Office, Inc., 2011 I6C2 CNA CNA PARAMOUNT Blanket Additional Insured - Owners, Lessees or Contractors - with Products-Completed Operations Coverage Endorsement This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is understood and agreed as follows: I. WHO IS AN INSURED is amended to include as an Insured any person or organization whom you are required by written contract to add as an additional insured on this coverage part, but only with respect to liability for bodily injury, property damage or personal and advertising injury caused in whole or in part by your acts or omissions, or the acts or omissions of those acting on your behalf: A. in the performance of your ongoing operations subject to such written contract; or B. in the performance of your work subject to such written contract, but only with respect to bodily injury or property damage included in the products-completed operations hazard, and only if: 1. the written contract requires you to provide the additional insured such coverage; and 2. this coverage part provides such coverage. II. But if the written contract requires: A. additional insured coverage under the 11-85 edition, 10-93 edition, or 10-01 edition of CG2010, or under the 10- 01 edition of CG2037; or B. additional insured coverage with "arising out of" language; or C. additional insured coverage to the greatest extent permissible by law; then paragraph I. above is deleted in its entirety and replaced by the following: WHO IS AN INSURED is amended to include as an Insured any person or organization whom you are required by written contract to add as an additional insured on this coverage part, but only with respect to liability for bodily injury, property damage or personal and advertising injury arising out of your work that is subject to such written contract. P,, Ill. Subject always to the terms and conditions of this policy, including the limits of insurance, the Insurer will not provide such additional insured with: A. coverage broader than required by the written contract; or B. a higher limit of insurance than required by the written contract. IV. The insurance granted by this endorsement to the additional insured does not apply to bodily injury, property damage, or personal and advertising injury arising out of: A. the rendering of, or the failure to render, any professional architectural, engineering, or surveying services, including: 1. the preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; and 2. supervisory, inspection, architectural or engineering activities; or B. any premises or work for which the additional insured is specifically listed as an additional insured on another endorsement attached to this coverage part. - V. Under COMMERCIAL GENERAL LIABILITY CONDITIONS, the Condition entitled Other Insurance is amended to add the following,which supersedes any provision to the contrary in this Condition or elsewhere in this coverage part: - CNA75079XX(10-16) Policy No: 4027219232 Page 1 of 2 Endorsement No: 8 AMERICAN CASUALTY CO OF READING,PA Effective Date: 09/15/2021 Insured Name: JOHNSON ENGINEERING, INC. Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office,Inc.,with its permission. 16C 2 CNA CNA PARAMOUNT Blanket Additional Insured - Owners, Lessees or Contractors - with Products-Completed Operations Coverage Endorsement Primary and Noncontributory Insurance With respect to other insurance available to the additional insured under which the additional insured is a named insured, this insurance is primary to and will not seek contribution from such other insurance, provided that a written contract requires the insurance provided by this policy to be: 1. primary and non-contributing with other insurance available to the additional insured; or 2. primary and to not seek contribution from any other insurance available to the additional insured. But except as specified above, this insurance will be excess of all other insurance available to the additional insured. VI. Solely with respect to the insurance granted by this endorsement, the section entitled COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: The Condition entitled Duties In The Event of Occurrence, Offense, Claim or Suit is amended with the addition of the following: Any additional insured pursuant to this endorsement will as soon as practicable: 1. give the Insurer written notice of any claim, or any occurrence or offense which may result in a claim; 2. send the Insurer copies of all legal papers received, and otherwise cooperate with the Insurer in the investigation, defense, or settlement of the claim; and 3. make available any other insurance, and tender the defense and indemnity of any claim to any other insurer or self-insurer,whose policy or program applies to a loss that the Insurer covers under this coverage part. However, if the written contract requires this insurance to be primary and non-contributory, this paragraph 3. does not apply to insurance on which the additional insured is a named insured. The Insurer has no duty to defend or indemnify an additional insured under this endorsement until the Insurer receives written notice of a claim from the additional insured. VII. Solely with respect to the insurance granted by this endorsement, the section entitled DEFINITIONS is amended to add the following definition: Written contract means a written contract or written agreement that requires you to make a person or organization an additional insured on this coverage part, provided the contract or agreement: A. is currently in effect or becomes effective during the term of this policy; and B. was executed prior to: 1. the bodily injury or property damage; or 2. the offense that caused the personal and advertising injury; for which the additional insured seeks coverage. Any coverage granted by this endorsement shall apply solely to the extent permissible by law. All other terms and conditions of the Policy remain unchanged. This endorsement, which forms a part of and is for attachment to the Policy issued by the designated Insurers, takes effect on the effective date of said Policy at the hour stated in said Policy, unless another effective date is shown below, and expires concurrently with said Policy. CNA75079XX(10-16) Policy No: 4027219232 Page 2 of 2 Endorsement No: 8 AMERICAN CASUALTY CO OF READING,PA Effective Date: 09/15/2021 Insured Name: JOHNSON ENGINEERING, INC. Copyright CNA All Rights Reserved. Includes copyrighted material of Insurance Services Office,Inc.,with its permission. 1 6 C JOHNENG-01 LHAMPTON ACORO' DATE(MM/DD/YYYY) CERTIFICATE OF LIABILITY INSURANCE 11/22/2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: JCJ Insurance Agency,LLC PHONE o,Ext):(321)445-1117 I FAX ) 2208 Hillcrest Street (A/C,No):(321 445-1076 Orlando,FL 32803 ADDREss:certs@jcj-insurance.com INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:Berkley Insurance Company 32603 INSURED INSURER B: Johnson Engineering,Inc. INSURER C: 2122 Johnson St. INSURER D: Fort Myers,FL 33901 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER D/POLICY EFF POLICY EXP LIMITS LTR INSD WVD (MM/DYYYYI (MM/DD/YYYY) COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ CLAIMS-MADE OCCUR DAMAGE TO RENTED PREMISES(Ea occurrence) $ MED EXP(Any one person) $ PERSONAL 8 ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ POLICY PRO- JECT LOC PRODUCTS-COMP/OP AGG $ OTHER: $ AUTOMOBILE LIABILITY Ea INED acccdent) SINGLE LIMIT ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY(Per accident) $ HIRED NON-OWNED PROPERTY'DAMAGE AUTOS ONLY AUTOS ONLY (Per accident) $ _ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION PER H AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANYY IPROPRIETOR/PARTNER E ECUTIVE N/A E.L.EACH ACCIDENT $ (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ A Professional Liab AEC-9047720-06 9/15/2021 9/15/2022 Per Claim 2,000,000 A AEC-9047720-06 9/15/2021 9/15/2022 Aggregate 2,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Contract No.21-7904-CEI Services for Construction Services for Hamilton Avenue CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier CountyBoard of CountyCommissioners THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 3295 Tamiami Trail East Naples,FL 34112 AUTHORIZED REPRESENTATIVE OA-a/ ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD l6C2 DIVISION OF CORPORATIONS DIVCACJI of '1 5irJ ' .org ' +>����,� �1'r Department of State / Division of Corporations / Search Records / Search by Entity Name / Detail by Entity Name Florida Profit Corporation JOHNSON ENGINEERING, INC. Filing Information Document Number 322710 FEI/EIN Number 59-1173834 Date Filed 11/03/1967 State FL Status ACTIVE Last Event CORPORATE MERGER Event Date Filed 03/05/2018 Event Effective Date NONE Principal Address 2122 JOHNSON STREET FORT MYERS, FL 33901 Changed: 03/17/2008 Mailing Address PO BOX 1550 FORT MYERS, FL 33902 Changed: 03/11/2009 Registered Agent Name&Address HOWARD, LONNIE V 2122 JOHNSON ST FT MYERS, FL 33901 Name Changed: 03/08/2012 Address Changed: 03/17/2008 Officer/Director Detail Name &Address Title President, Director Howard, Lonnie V Report Year Filed Date 1, V C 2019 04/01/2019 2020 04/13/2020 2021 04/05/2021 Document Images 04/05/2021--ANNUAL REPORT View image in PDF format 04/13/2020—ANNUAL REPORT View image in PDF format 04/01/2019--ANNUAL REPORT View image in PDF format 03/28/2018—ANNUAL REPORT View image in PDF format 03/05/2018—Merger View image in PDF format 03/17/2017--ANNUAL REPORT View image in PDF format 03/28/2016--ANNUAL REPORT View image in PDF format 03/11/2015--ANNUAL REPORT View image in PDF format 03/10/2014--ANNUAL REPORT View image in PDF format 03/18/2013--AMENDED ANNUAL REPORT View image in PDF format 01/17/2013—ANNUAL REPORT View image in PDF format 06/29/2012--ANNUAL REPORT View image in PDF format 03/08/2012—ANNUAL REPORT View image in PDF format 01/31/2011--ANNUAL REPORT View image in PDF format 03/09/2010--ANNUAL REPORT View image in PDF format 03/11/2009--ANNUAL REPORT View image in PDF format 03/17/2008--ANNUAL REPORT View image in PDF format 03/13/2007--ANNUAL REPORT View image in PDF format 03/29/2006--ANNUAL REPORT View image in PDF format 03/16/2005—ANNUAL REPORT View image in PDF format 03/19/2004--ANNUAL REPORT View image in PDF format 03/31/2003--ANNUAL REPORT View image in PDF format 09/11/2002--Amended and Restated Articles View image in PDF format 03/31/2002--ANNUAL REPORT View image in PDF format 03/23/2001 --ANNUAL REPORT View image in PDF format 03/15/2000—ANNUAL REPORT View image in PDF format 03/01/1999--ANNUAL REPORT View image in PDF format 02/09/1998--ANNUAL REPORT View image in PDF format 03/19/1997—ANNUAL REPORT View image in PDF format 02/01/1996--ANNUAL REPORT View image in PDF format 02/03/1995--ANNUAL REPORT View image in PDF format f.o n1 ia:tn; i