The URL can be used to link to this page

Agenda 01/12/2021 Item #16A27 (Modification to Agreement NO. H0309)01/12/2021 EXECUTIVE SUMMARY Recommendation to reinstate Subgrant Agreement No. H0309 and approve the Modification to Subgrant Agreement No. H0309 with the Florida Division of Emergency Management to extend Subgrant Agreement No. H0309 to October 31, 2021, and approve an Amendment revising the Effective Date to Professional Services Agreement No. 20-7678 with Agnoli Barber & Brundage, Inc., approved by the Board on November 10, 2020 for the Solana Road Drainage Project (Project No. 60102). OBJECTIVE: To reinstate and extend the period of performance under Subgrant Agreement No. H0309 (the “Subgrant Agreement”) with the Florida Division of Emergency Management (“FDEM”) and to approve an Amendment to Professional Services Agreement No. 20-7678 to make the effective date the same as the reinstatement date of Subgrant Agreement No. H0309. CONSIDERATIONS: On September 11, 2018, (Agenda Item 16.E.3) the Board provided after-the- fact approval for the submittal of several applications for Hazard Mitigation Grant Progr am funding. Capital Project Planning, Impact Fees and Program Management submitted eight (8) grant applications for funding of which the Solana Road Drainage Project application was approved for funding and attached for execution. The Solana Road project award is for the design and permitting of an improved stormwater conveyance system to help alleviate historical flooding in the Solana Road/Burning Tree area. On December 10, 2019, (Agenda Item 16.A.27), the Board approved the Subgrant Agreement for grant funding. On October 13, 2020, (Agenda Item 16.A.24), the Board approved a Modification to the Subgrant Agreement extending the contract expiration date to October 30, 2021. Although County staff timely returned the Board approved partially executed Modification to the Subgrant Agreement to FDEM, FDEM did not timely execute the Subgrant Agreement before it expired on October 30, 2020, and is now requesting that the County reinstate and extend the Subgrant Agreement by approving the attached Modification to Subgrant Agreement Between the Division of Emergency Management and the Collier County Board of County Commissioners as requested by FDEM. Also related to this request for approval is Professional Services Agreement No. 20 -7678, which concerns the provision of consulting services in furtherance of the Subgrant Agreement. The Board approved Professional Services Agreement No. 20-7678 on November 10, 2020, (Agenda Item 16.A.14); which is after the Subgrant Agreement expired. In order to obtain reimbursement under the grant, the effective date of Agreement No. 20-7678 cannot predate the Subgrant Agreement and the design contract is required to be submitted to FDEM within ten days of execution. To cure this issue, staff is attaching an Amendment to Professional Services Agreement No. 20-7678, which will revise the Effective Date and date of execution of that agreement to the Board’s anticipated approval date of January 12, 2021. FISCAL IMPACT: Costs for design total $505,761.55. Funds in the amount of $69,750.00 are available within the GMD Grant Fund (711), Project 60102. Funds in the amount of $23,250.00 are available within the GMD Grant Match Fund (712), Project 60102. Funds in the amount of $412,761.55 are available within Stormwater Bond Fund (327). Funding sources include a FEMA Hazard Mitigation grant passed through FDEM, ad valorem revenue and stormwater infrastructure bonds. LEGAL CONSIDERATIONS: This item is approved as to form and legality and requires majority vote for Board approval. -SRT 16.A.27 Packet Pg. 958 01/12/2021 GROWTH MANAGEMENT IMPACT: Approval of this item is in accordance with the goals and objectives of the Drainage Sub-element of the Growth Management Plan. RECOMMENDATION: Recommendation to reinstate Subgrant Agreement No. H0309 and approve the attached Modification to Subgrant Agreement No. H0309 with the Florida Division of Emergency Management to extend Subgrant Agreement No. H0309 to October 31, 2021, approve an Amendment revising the Effective Date to Professional Services Agreement No. 20 -7678 with Agnoli Barber & Brundage, Inc., and authorize the Chair to sign both agreements. Prepared by: Gary R. Putaansuu, P.E. Project Manager, Capital Project Planning, Impact Fees and Program Management Division ATTACHMENT(S) 1. Modification to Agreement H0309 (PDF) 2. [Linked] First Amendment to Professional Services Agreement 20-7678 (PDF) 3. 20-7678 AgnoliBarberBrundage_Contract (003) (PDF) 4. AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (PDF) 16.A.27 Packet Pg. 959 01/12/2021 COLLIER COUNTY Board of County Commissioners Item Number: 16.A.27 Doc ID: 14380 Item Summary: Recommendation to reinstate Subgrant Agreement No. H0309 and approve the Modification to Subgrant Agreement No. H0309 with the Florida Division of Emergency Management to extend Subgrant Agreement No. H0309 to October 31, 2021, and approve an Amendment revising the Effective Date to Professional Services Agreement No. 20-7678 with Agnoli Barber & Brundage, Inc., approved by the Board on November 10, 2020 for the Solana Road Drainage Project (Project No. 60102). Meeting Date: 01/12/2021 Prepared by: Title: Project Manager, Senior – Capital Project Planning, Impact Fees, and Program Management Name: Gary Putaansuu 12/04/2020 11:08 AM Submitted by: Title: Division Director - IF, CPP & PM – Capital Project Planning, Impact Fees, and Program Management Name: Amy Patterson 12/04/2020 11:08 AM Approved By: Review: Capital Project Planning, Impact Fees, and Program Management Gerald Kurtz Additional Reviewer Completed 12/14/2020 5:44 PM Capital Project Planning, Impact Fees, and Program Management Amy Patterson Additional Reviewer Completed 12/15/2020 11:14 AM Growth Management Department Lisa Taylor Additional Reviewer Completed 12/15/2020 12:33 PM Growth Management Department Lisa Abatemarco Additional Reviewer Completed 12/16/2020 1:53 PM Growth Management Department Jeanne Marcella Level 1 Reviewer Completed 12/16/2020 2:02 PM Growth Management Department Thaddeus Cohen Department Head Review Completed 12/17/2020 9:20 AM Grants Valerie Fleming Level 2 Grants Review Completed 12/18/2020 8:14 AM County Attorney's Office Scott Teach Level 2 Attorney Review Completed 12/18/2020 11:37 AM Grants Carrie Kurutz Additional Reviewer Completed 12/21/2020 11:39 AM Office of Management and Budget Debra Windsor Level 3 OMB Gatekeeper Review Completed 12/22/2020 8:22 AM Office of Management and Budget Laura Zautcke Additional Reviewer Completed 12/22/2020 12:55 PM County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 12/22/2020 2:10 PM Grants Therese Stanley Additional Reviewer Completed 12/29/2020 9:44 AM County Manager's Office Dan Rodriguez Level 4 County Manager Review Completed 12/31/2020 9:34 AM 16.A.27 Packet Pg. 960 01/12/2021 Board of County Commissioners MaryJo Brock Meeting Pending 01/12/2021 9:00 AM 16.A.27 Packet Pg. 961 16.A.27.aPacket Pg. 962Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 963Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 964Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 965Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 966Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 967Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 968Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 969Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.aPacket Pg. 970Attachment: Modification to Agreement H0309 (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 Reinstatement and 16.A.27.dPacket Pg. 971Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 972Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 973Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 974Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 975Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 976Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 977Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 978Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 979Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 980Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 981Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 982Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 983Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 984Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 985Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 986Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 987Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 988Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 989Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 990Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 991Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 992Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 993Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 994Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 995Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 996Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 997Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 998Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 999Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1000Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1001Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1002Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1003Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1004Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1005Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1006Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1007Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1008Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1009Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1010Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1011Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1012Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1013Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1014Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1015Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1016Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1017Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1018Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1019Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1020Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1021Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1022Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1023Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1024Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1025Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 16.A.27.dPacket Pg. 1026Attachment: AGRMT 2020 02-13 FEMA HMGP 4337-192-R H0309 (1) (14380 : Solana Road Stormwater Project Subgrant Agreement No. H0309 FIRST AMENDMENT TO PROFESSIONAL SERVICES AGREEMENT # 20-7678 SOLANA ROAD STORMWATER IMPROVEMENTS DESIGN SERVICES THIS FIRST AMENDMENT made and entered into on this 12th day of January 2020, by and between Agnoli, Barber & Brundage, Inc. (the "Consultant") and Collier County, a political subdivision of the State of Florida, (the "County"). WHEREAS, on November 10, 2020 (Agenda Item No. 16.A.14), the County approved entering into Agreement # 20-7678 (the "Agreement," attached hereto as Exhibit "A") with Consultant to provide professional design and related services on the Solana Road Stormwater Improvements Design Services project; and WHEREAS, the Agreement concerns the provision of services in furtherance of Florida Division of Emergency Management ("FDEM'l Subgrant Agreement No. H0309, which grant provides funding for the design and permitting of an improved sormwater conveyance system to help alleviate historical flooding in the Solana Road/Burning Tree Drive area in Collier County, Florida; and WHEREAS, the Parties acknowledge and concur that no services were commenced or initiated either through the issuance of a Work or Purchase Order and that the Parties desire to amend the Agreement to provide for a new effective date to coincide with the anticipated approval date of the reinstatement and extension date of Subgrant Agreement No. H0309, which is scheduled for approval by the County on January 12, 2021. NOW, THEREFORE, in consideration of the mutual promises and covenants herein contained, it is agreed by the Parties as follows: 1. The Effective Date and the date that the Parties entered into Agreement # 20-7678 shall be amended to state January 12, 2021, consistent with the approval date of the reinstatement and extension date of Subgrant Agreement No. H0309, which date is hereby incorporated into the Agreement. 2. All other terms and conditions, as amended, shall remain the same. SIGNATURE PAGE TO FOLLOW "Remainder of this page left blank intentionally" Page I of 3 First Amendment to Agreement # 20-7678 10 IN WITNESS WHEREOF, the Parties have each executed this Fiat Amendment by an authorized person or agent on the date and year first written above. ATTEST: Crystal K. Kinzel, Clerk of Courts & Comptroller EIS Dated: (SEAL) Cons ul is Witnesses: kirst Witness Denise Rakich TTyp riot witness nameT Second Witness Andrea Anderson TType/print witness nameT BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA By: Penny Taylor, Chair CONSULTANT: Agnoli Barber & Br age, Inc. By: Signature Dominick J. Amico, P.E., President TType/print signature and titleT M-- Approved as to Form and Legality: Teach, Deputy County Attomey Page 2 of 3 First Amendment to Agreement # 20-7678 EXHIBIT A Page 3 3 O First Amendment to Agreement # 20-7678 CAO PROFESSIONAL SERVICES AGREEMENT Contract # 20-7678 for _Solana Road Stormwater Improvements Design ,._ ,.,.. „Services THIS AGREEMENT is made and entered into this day of , 20 20 by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and Agnoli, Barber & Brundage, Inc. authorized to ,.,.,do business in the State of Florida, whose business address is 2770 South Horseshoe Drive, Suite 7,_Naples, FL 34104 (hereinafter referred to as the "CONSULTANT" and/or "CONTRACTOR") WITNESSETH; WHEREAS, the COUNTY desires to obtain the professional services of the CONSULTANT concerning Solana Road Stormwater improvements Design Services (hereinafter referred to as the "Project"), said services in accordance with the provisions of Section 287.055, Florida Statutes being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; and WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows, - ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to COUNTY professional services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the COUNTY for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Page 1 of 32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 CA( Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to the COUNTY. 1.5. CONSULTANT designates Dominick J. Armco, P.E. a qualified licensed professional to serve as the CONSULTANT's project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without the COUNTY's prior written approval, and if so removed must be immediately replaced with a person acceptable to the COUNTY. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from the COUNTY to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to the COUNTY. 1.7. The CONSULTANT represents to the COUNTY that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the COUNTY's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218,735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows; IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Page 2 of 32 S'SA_CCNA Sin& Yro}ecr AgreemeM2013A10 Ver.3 cr�� Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8999 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 1.8. In the event of any conflicts in these requirements, the CONSULTANT shall notify the COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY regarding resolution of each such conflict. The COUNTYS approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project 1.9. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following; Tasks not completed within the expressed time frame, including required deliverables, incomplete andlor deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to CONSULTANT's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY reserves the right to make sole determination regarding deductions. After notification of deficiency, if the CON SULANT fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge the Page 3 of 32 PSA_CCNA Single Project Agreement 2017.010 Vera CONSULTANT for services and/or items necessary to correct the deficiencies directly related to the CONSULTANT's non-performance whether or not the COUNTY obtained substitute performance. 1.10. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without the COUNTY's prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt written notice of any such subpoenas. 1,11, As directed by the COUNTY, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), orwhen implemented, derived from the RTK (Real - Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have common naming conventions (i.e, right-of-way - ROW, centerlines - CL, edge -of -pavement - EOP, etc.), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT 2.1. If authorized in writing by the COUNTY through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in the COUNTY's Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by the COUNTY as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. The COUNTY will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder, If the COUNTY determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to the COUNTY of the emergency within forty- eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT's right it otherwise may have had to seek an adjustment to its compensation or time of performance under this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: Page 4 of 32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 2.2. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.3. Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, the COUNTY's schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by the COUNTY when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT's control and fault. 2.4. Providing renderings or models for the COUNTY's use. 2.5. Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting the COUNTY in obtaining such process licensing. 2.6. Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.7. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by the COUNTY, other than visits to the Project site or the COUNTY's office. 2.8. Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2,9. Preparing to serve or serving as a CONSULTANT or witness for the COUNTY in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as past of the Basic Services to be provided herein). 2.10. Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice, ARTICLE THREE THE COUNTY'$ RESPONSIBILITIES 3.1, The COUNTY shall designate in writing a project manager to act as the COUNTY's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define the COUNTY's policies and decisions with respect to CONSULTANT's services for the Project. However, the Project Manager is not authorized to issue any verbal or written orders or instructions to the CONSULTANT that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever. Page 5 of 32 €'SA_CCNA Slagle Project Agreement 2017,010 Ver 3 0 a. The scope of services to be provided and performed by the CONSULTANT hereunder; b. The time the CONSULTANT is obligated to commence and complete all such services; or c. The amount of compensation the COUNTY is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: a. Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; b. Provide all criteria and information requested by CONSULTANT as to the COUNTY 's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, Flexibility and expandability, and any budgetary limitations; c. Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT's disposal all available information in the COUNTY's possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; d. Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the COUNTY with respect to the services to be rendered by CONSULTANT hereunder. ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from the COUNTY for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement, 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or lock -outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT's services from any cause whatsoever, including those for which the COUNTY may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from the COUNTY, CONSULTANT's sole remedy against the COUNTY will be the right to seek an extension of time to its schedule provided, however, the granting of any such time extension shall not be a condition Page 6 of 32 PSA_CCNA Single Project Agreement 2017,01 D Ver3 precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT's compensation shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the COUNTY's satisfaction that the CONSULTANT's performance is or will shortly be back on schedule. 4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by the COUNTY to CONSULTANT be deemed a waiver of any right or claim the COUNTY may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the COUNTY for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof, The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction of the COUNTY's Project Manager before payment for the fixed price contract is authorized, Time and Materials: The COUNTY agrees to pay the contractor for the amount of labor time spent by the CONSULTANT's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's mark-up), This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. 5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above, X Grant Funded: The hourly rates as set forth and identified in Schedule B, which is attached hereto, are for purposes of providing estimate(s), as required by the grantor agency. Page 7 of 32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 ARTICLE SIX THE OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by the COUNTY, CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement ("Project Documents"). The COUNTY shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to the COUNTY the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 5.2. Notwithstanding anything in this Agreement to the contrary and without requiring the COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use on this Project. CONSULTANT warrants to the COUNTY that it has full right and authority to grant this license to the COUNTY. Further, CONSULTANT consents to the COUNTY's use of the Project Documents to complete the Project following CONSULTANT's termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project_ CONSULTANT also acknowledges the COUNTY may be making Project Documents available for review and information to various third parties and hereby consents to such use by the COUNTY. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder, The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and hold harmless the COUNTY, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph 8.11. ?age 8 of 32 PSA_CCNA Single Project Agreement 201T.010 Ver 3 8.2. To the extent that the Agreement that the work pertains to a "Professional Services Contract" as defined in Section 725.08(3), Florida Statutes, and the CONSULTANT is a "Design Professional" as defined in Section 725.08(4), Florida Statutes, the indemnification provided herein shall be limited as provided in Sections 725.08(1) & (2), Florida Statutes, ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, 'insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2. All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3. All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests' provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against the COUNTY for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by the COUNTY applicable to this Project. 9.3.4. The Certificates of Insurance must read. For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. 9.4. CONSULTANT, its subconsultants and the COUNTY shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by the COUNTY, except such rights as they may have to the proceeds of such insurance held by any of them. 9.5. All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements; 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. Page 9 of 32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff, unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this Agreement shall, however, be construed as constituting an agreement between the COUNTY and any such other person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third party any claim or right of action against the COUNTY beyond such as may then otherwise exist without regard to this Agreement. 10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. All personnel, identified in Schedule F shall not be removed or replaced without the COUNTY's prior written consent. 10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the COUNTY. Each subconsultant or subcontract agreement shall preserve and protect the rights of the COUNTY under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the sub consulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub- subconsultants or sub -subcontractors, 10.4. CONSULTANT acknowledges and agrees that the COUNTY is a third -party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between the COUNTY and any subconsultant or subcontractor. Further, all such contracts shall provide that, at the COUNTY's discretion, they are assignable to the COUNTY upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS 11.1. CONSULTANT's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the COUNTY arising out of this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANTs services nor payment by the COUNTY shall be deemed to be a waiver of any of the COUNTY's rights against CONSULTANT. Page 10of32 PSA_CCNA Single Project Agreement 2017,DID Ver 3 ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for the COUNTY to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT's failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT's failure to properly and timely perform the services to be provided hereunder or as directed by the COUNTY, or (c) the bankruptcy or insolvency or a gene4 assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT's principals, officers or directors, or (d) CONSULTANT's failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT' failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The COUNTY may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below, 12.3. The COUNTY shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT_ In the event of such termination for convenience, CONSULTANT'S recovery against the COUNTY shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against the COUNTY, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. 12.4. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the COUNTY all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Article 6, that are in CONSULTANTS possession or under its control, 12.5. The COUNTY shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 12.6. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) the COUNTY otherwise persistently fails to fulfill some material Page 11 of 32 PSA CCNA Single Project Agreement 2017.010 Ver.3 obligation owed by the COUNTY to CONSULTANT under this Agreement, and (ii) the COUNTY has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving THE COUNTY a second fourteen (14) days written notice of CONSULTANT's intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to the COUNTY of CONSULTANT's intent to terminate this Agreement. If the COUNTY does not cure its default within fourteen (14) days after receipt of CONSULTANT's written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the COUNTY, terminate the Agreement and recover from the COUNTY payment for Services performed through the termination date, but in no event, shall CONSULTANT be entitled to payment for Services not performed or any other damages from the COUNTY. ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. 13.2. In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the CONSULTANT agrees to execute the required Truth -In -Negotiation Certificate, attached hereto and incorporated herein as Schedule E, certifying that wage rates and other tactual unit costs supporting the compensation for CONSULTANT's services to be provided under this Agreement are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees that the original Agreement price and any additions thereto shall be adjusted to exclude any significant sums by which the COUNTY determines the Agreement price was increased due to inaccurate, incomplete, or non -current wage rates and other factual unit costs. All such adjustments shall be made within one (1) year following the end of this Agreement. ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1, CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1, No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. Page 12 of 32 PSA_CCNA Single Project Agreement 2017.010 VeT.3 ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 161. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following the COUNTY's address of record: Board of County Commissioners for Collier County, Florida Division Name: Capital Project Planning, Impact Fees, and Program Mangement Division Director: Amy Patterson Address: 2685 Horseshoe Drive S Naples, FL 34104 Administrative Agent/PM: Gary Putaansuu, Senior Project Manager Telephone: (239) 252-5876 E-Mail(s): Ga .Putaansuu colliercount ov 16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT's address of record: Company Name: A noli Barber 8t Brundage, Inc. Address: 7400 Trail Boulevard _Suite 200 Naples, FL 34108 Attention Name & Title: Dominick J. Armco Telephone: (239)537-3111 T E-Mail(s): amicoCa)abbinc.com 16.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. ARTICLE SEVENTEEN MISCELLANEOUS 17.1. CONSULTANT, in representing the COUNTY, shall promote the best interests of the COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair dealing. Page 13 of 32 P5A_CCNA Single Project Agreement 2017.010 Ver.3 OW 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of the COUNTY. 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 17.6. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 17.8. This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 17.9. The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE Schedule E CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE Schedule F KEY PERSONNEL Schedule G Other: Federal Grant Contract Provisions Solicitation # 20-7678 including all Attachment(s), Exhibits) & Addendum Consultant's Proposal 17.10. Grant Funded Projects only applicable to Grant funded projects): In the event of any conflict between or among the terms of any of the Contract Documents and/or the COUNTY's Board approved Executive Summary, the terms of the Agreement shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Grant Conditions shall take precedence over the Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved by application of the Supplemental Conditions, if any, or the Agreement, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the CONSULTANT at the COUNTY's discretion. Page 14 of32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 10 ARTICLE EIGHTEEN APPLICABLE LAW 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE NINETEEN SECURING AGREEMENTIPUBLIC ENTITY CRIMES 19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. At the time this Agreement is executed, CONSULTANT shall sign and deliver to the COUNTY the Truth -in -Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E, CONSULTANT's compensation shall be adjusted to exclude any sums by which the COUNTY determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work,, may not submit bids, proposals, or replies on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." ARTICLE TWENTY DISPUTE RESOLUTION 20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision -making authority and by the COUNTY's staff person who would make the presentation of any settlement reached during negotiations to the COUNTY for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties Page 15 of 32 PSA_CCNA Single Project Agreement 2017 M Ver,3 arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision -making authority and by the COUNTY's staff person who would make the presentation of any settlement reached at mediation to the COUNTY`s board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 20.2. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE TWENTY-ONE IMMIGRATION LAW COMPLIANCE 21.1. By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the COUNTY shall have the discretion to unilaterally terminate this Agreement immediately, Page 16 of32 PSA_CCNA Single Project Agreement2017.010 Ver.3 IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement the day and year first written above. ATTEST: Crystal K. Kinzel, Clerk of Courts & Comptroller By Date: Y GAG ,Attest as to Chairmen's signature only. Aed s to�rri)` and Legality: County Attorney Name Consultant's Witnesses: r n ` nss e 4 c,,fi► JName and Title Witness An-lr�� And�rsm� K Ili�ec{fl✓ Name and Title BOARD OF COUNTY COMMISSIONERS FOR COLLIER COUNTY, FLORIDA Burt L. Saunders , Chairman Consultant: Agnoli, Barber & Brundage, Inc. By: Dominick J. Amico, P.E., President Name and Title Page 17 of 32 PSA_CCNA Singk Pmjecr Agreement 2017.010 Vcc3 SCHEDULE A SCOPE OF SERVICES © following this page (pages 1 through L Page 18 of32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 SCHEDULE A — SCOPE OF SERVICES 20-7678 — Solaoa Road Stormwater Improvements Design Services BACKGROUND Solana Road Stormwater Improvements project is a part of the Gordon River Master Plan. The purpose of the project is to reduce upstream flooding by improving the capacity of approximately 2,000 feet of culvert and 1,000 feet of open ditch. The project is located along the north side of Solana Road starting from the west side of Goodlette-Frank Road and ending at the outfall into the Gordon River east of Burning Tree Drive, in Collier County, Florida. PURPOSE The purpose of this scope of work is to describe the responsibilities of the CONSULTANT and the COUNTY in connection with the design and preparation of a complete set of construction contract plans and special provisions, if necessary, for: Construction of a box culvert to replace existing pipes/culverts beginning on the west side of Goodlette-Frank Road north of the intersection of Solana Road, crossing under Goodlette-Frank Road, and continuing downstream along the north side of Solana Road to a point east of Burning Tree Drive where it discharges into an open ditch. Then reconstruction of approximately 1,000 feet of open ditch from the box culvert end to an outfall at the upper Gordon River. Design Services shall include a review of the Gordon River Master Plan recommendation for Solana Road to verify the need for the increased capacity to relieve upstream flooding, the size of culvert needed, and, should the recommendation be to replace the existing 4'x 8' box culvert, perform a cost benefit analysis to evaluate options to allow it to remain in place, The general objective is for the CONSULTANT to prepare a set of plans to be used by the contractor to build the project, and by COUNTY to ensure the project is built as designed and to specifications. Elements of work shalt include roadways, drainage structures, geotechnical activities, survey, drainage, signing and pavement markings, utility relocation, maintenance of traffic, cost estimates, environmental permits, environmental mitigation plans, quantity computation books, and al I necessary incidental items for a complete project. The Scope of Services establishes which items of work described in the 1~DOT Plan Preparation Manual(s), and other pertinent manuals to accomplish the work, are specifically included in this contract; and, which of the items of work will be the responsibility of the CONSULTANT or the COUNTY, All plans and design documents are to be prepared with standard English values in accordance with all applicable Florida Department of Transportation (hereinafter referred to as FDOT) Manuals and guidelines. The CONSULTANT shall be aware that as a project is developed, certain modifications and/or improvements to the original recommendation may be required. The CONSULTANT is to incorporate these refinements into the design and will consider this effort to be an anticipated and integral part of the work. This will not be a basis for any supplemental fee request(s). Page I of 7 G:U_ALL SOLICITATIONS & TEMPLATESU_FY 2020\20-7678 Solana Road Stormwater Improvements Pesign120- 7678_5chedvieA_ScopeofServices.docx The CONSULTANT shall demonstrate good project management practices while working on this project. These include communication with the COUNTY and others as necessary, management of time and resources, and documentation. The CONSULTANT shall set up and maintain throughout the design of the project a contract file. It shall be the CONSULTANT's responsibility to utilize the very best engineering judgment, practices and principles possible during the prosecution of the work commissioned under this Agreement. The COUNTY will provide contract administration, management services, and technical reviews of all work associated with the development and preparation of the contract plans. The COUNTY will provide job specific information and/or functions as outlined in this Agreement. Task Description i. Preliminary Discovery - The Consultant will review printed literature including topographic maps, aerial photography (including historic photos) and ground water resources. CONSULTANT shall identify areas with problematic soil and groundwater conditions, including: • Record drawings research • SFWMD pre -application meeting • City of Naples coordination including new record drawing information • Neighborhood outreach including Royal Poinciana Country Club • FDEM schedule update Deliverables; o Electronic copies of record drawings obtained o SFWMD pre -application meeting notes o City of Naples coordination including new record drawing information o Electronic copies of any outreach materials/correspondence o FDEM schedule 1 SurveyinE- The Consultant will perform a survey with site -specific data gathering in the process of developing the design of this project, including: • Depict alignment and/or existing R/W lines (in required format) per COUNTY RIW Maps, platted or dedicated rights of way. • Perform 3-dimensional (X,Y,Z) field location, or stakeout, of boring sites established by geotechnical engineer, includes field edits, analysis and processing of all field collected data and/or reports. • Provide work zone as required by FDOT standards. • Perform all activities required to supervise and coordinate project. These activities must be performed by the project supervisor, a Florida Professional Surveyor. • Horizontal and vertical control • Route boundary survey and inventory of inlets, manholes, etc. Page 2 of 7 GM ALL SOLICITATIONS & TEMPLA"rESA FY 2020120-7678 Solana Read Stormwaicr Improvements Designl20- 7678_ScheduleA Scopeofservices.docx • Site topography survey • Channel and floodplain cross sections at outfall • Coordination of Subsurface Utility Exploration (SUE) • Documentation Deliverables: o Survey to be used as base mapping for construction plans. As such the survey is for ABB Design use. A pdf file with topo points and existing topographic features will be submitted. Please note this is not a boundary survey or official survey document. Surveying (Subconsultant) Subsurface Utility Exploration (SUE) Locate utilities using Ground Penetrating Radar (GPR) and Radio Detection. Paint and flag findings. Perform 12 soft digs (natural ground) and 12 digs (asphalt/concrete) using vacuum excavation, locations to be determined by ABB and County Project Manager. Dcliverat les; o SUE to be used as base mapping for construction plans_ As such the SUE is for ABB Design use. A pdf file with horizontal locations for GPIR and x, y, z locations for the soft digs will be submitted, 2 Geotechnicai _(Subconsultant) - Provide geotechnical recommendations regarding the proposed stormwater construction project including the following: description of the site/alignment, design recommendations and discussion of any special considerations (i.e. removal of unsuitable material, consolidation of weak soils, estimated settlement time/amount, groundwater control, high groundwater conditions relative to pavement base, etc.). Also included: • Review available soil information • Standard penetration tests every 500' • GW level measurements • Visual and lab classifications • Subsurface assessment and engineering evaluation Deliverables: o Geotechnicai Exploration Report. 3 Basis of Design Report (BDOR) JABB) Page 3 of 7 6:%1 ALL SOLICITATIONS &'rEMPLATESII_FY 2020\20-7678 Solana Road Stormwater improvements Design%20- 7678_Schedul eA _Scopeo fS ery i ces.docx • Site characterization • Update H&H modeling and assess hydraulic performance of existing system • Cost benefit analysis (Options Analysis) (2 alternatives and the base project) • Develop recommended hydraulic design • Document BDOR Deliverables: o Cost benefit analysis of alternative and the base project o Draft BDOR o Final BDOR 3 Basis of Design Report (BDOR) (S.ubconsultan� • Update H&H modeling and assess hydraulic performance of existing system • Cost benefit analysis (Options Analysis) (2 alternatives) • Develop recommended hydraulic design Deliverables: o To be submitted by Consultant 4 Final Design. The Consultant will deliver the plans depicting where the project impact existing roadways, drainage features, existing utilities, existing signing, pavement markings, and structures and the plans and specifications will describe how to restore them. • 60% design formulation • Structural engineering coordination • Landscape design • Review and final design • Benefit cost analysis — per Grant Agreement • Constructability review • Engineer's estimate of probable cost • Develop plans and specifications Deliverables: 0 60% design plans 0 60% Engineer's estimate of probable cost o Final design plans o Final Engineer's estimate of probable cost o Benefit cost analysis o Plan specifications Page 4 of 7 Gall ALL SOLICITATIONS & TFMALATESII FY 2020120-7679 Solana Road Storm water Improvements Design120- 7678_Schedu IeA_s copeof5ery ices,docx 4 Final ❑esi n Subconsultant Structural engineering Engineer's estimate of probable cost Deliverables: o Design plans and EOPC to be included with Consultant's submittals 5 Public Involvement - Public involvement is an important aspect of the project development process. Public involvement includes communicating to all interested persons, groups, and government organizations information regarding the development of the project, Property owners adjacent to project, including those that use the golf courses, shall be informed about the project. Public Meetings may be held on this project at the 66% design stage. In addition, the Consultant and County stag will meet with civic groups and others on an individual basis, as needed, to discuss the project. • Project open house (1) Deliverables; o Design displays presented at meeting 5 Public involvement (Subconsultant) • Project open house (1) Deliverables: o Press release o Project handouts a Sign -in sheet o Comment cards o Meeting summary 6 Permittine- The Consultant will apply for and secure all necessary permits needed to buitd the project, including: ERP and dewatering application for SFWMD • SFWMD pre-app (recommended to be done at project start) Page 5 of 7 G:II ALL SOLICITATIONS & TEMPLATEW FY 2020\20-7678 Solana Road Stormwater Impmvements DesignQ0- 7678_Schedu l eA __Scopeo fS eryices.docx • Right of Way permit • Respond to RAN • Final Permit procurement Deliverables- * Electronic copies of all permit submittals o Electronic copies of all RAls o Electronic copies of all permits 6 Permitting (Subconsultant) Environmental assessment of project and T&E species evaluation Deliverables: o Environmental Assessment o T&E Species Evaluation 7 Post-Desien Service (ABB) • Utility coordination • Bid documents • Bidding assistance • Letter of Recommended Award • Contractor Reference Check Engineer of Record services during construction • Shop drawing review and approval Record drawings and final construction certification (5) Deliverables; o Letter of Recommended Award o Contractor references o Electronic copies of all shop drawing reviews o Record drawings o Construction/permit certifications 7 Post_Duhm Service (Subconsultant • Shop drawing review and approval Deliverables: }'age 6 of 7 G:%I ALL SOL1C[TATTONS & TEMPLATESI[_FY 2020QO-7678 Solana Road Stormwater lmpmvements Dcsign%20• _ '36?$_Sctredu4eA_Scc�peoi5ery iccs.docx C.��f o Electronic copies of all shop drawing reviews Reimbursabtes As allowed under the contract Note: Monthly progress billings are not tied to deliverables. Some tasks will take multiple billing periods to complete to the deliverable stage. Progress billings will be allowed prior to deliverable provision. Page 7 of 7 G;11_ALL SOLICITATIONS & TEMPLATESA FY 2020QO.7678 Solana Road Stormwater Improvements Design120- 7678_S cheduicA_5copeo fSeryi=.derx SCHEDULE B BASIS OF COMPENSATION 1. MONTHLY STATUS REPORTS 8.1.1. As a condition precedent to payment, CONSULTANT shall submit to the COUNTY as part of its monthly invoice a progress report reflecting the Project status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1, For the Basic Services provided for in this Agreement, the COUNTY agrees to make the payments to CONSULTANT in accordance with the terms stated below. Payments will be made in accordance with the following Schedule; however, the payment of any particular line item noted below shall not be due until services associated with any such line item have been completed or partially completed to the COUNTY's reasonable satisfaction. Lump sum payments will be made upon the percentage complete. In no event shall such Time and Materials compensation exceed the amounts set forth in the table below. :Taksrl#em Description Lump Sum Time and 11�a�erifa[� E Not Ekee4d Preliminary Discovery $ $15,870.00 1 Surveying (ABB) $ $41,901.00 1 Surveying (Subconsultant) $10,840.00 $ 2 Geotechnical(Subconsultant) $6,742.00 $ 3 Basis of Design Report (BDOR) (ABB) $ 29,822.00 3 Basis of Design Report (BDOR) (Subconsultant,) $53.068.00 $ 4 Final Design (ABB) $ $ 87,756.00 4 Final Design (Subconsultant $ 66.246,00 $ 5 Public Involvement (ABB) $ $ 5,083.00 5 Public Involvement (Subconsultant) $ 18,500.00 $ 6 Permitting (ABB) $ $ 33,965.00 6 Permitting (Subconsultant) $ 29,185.00 $ 7 Post -Resign Services (ABB) $ $ 88,620.00 7 Post -Design Services (Subconsultant) $4,900.00 $ Reimbursables $ 3,600.00 $ 5% Subconsultant Mark -Up $ 9,473.55 $ $ $ $ $ Total Lump Sum Fee $202,744.55 $ Total Time and Materials Fee $ $ 303,017.00 GRAND TOTAL FEE $505.761.55 $ $ Page 19 of 32 PSA—CCNA Single Project Agreement 2017.010 Ver 3 6.2.2. p* Time and Material Fees: The fees noted in Section B.2.1, shall constitute the amounts to be paid to CONSULTANT for the performance of the Basic Services. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT's personnel, with respect to this Project, including all indirect payroll related costs and fringe benefits, all in accordance with and not in excess of the rates set forth in the Attachment 1 to this Schedule B. IArith each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by the COUNTY, regarding CONSULTANT's Direct Labor Costs incurred at the time of billing, to be reviewed and approved by the COUNTY, There shall be no overtime pay without the COUNTY's prior written approval. B.2.2.1. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has completed such task as of that particular monthly billing. B.2.3. p" Lump Sum Fees: The fees noted in Section 2.1. shall constitute the lump sum amount to be paid to CONSULTANT for the performance of the Basic Services. There shall be no overtime pay without the COUNTY's prior written approval. B.2.3.1 CONSULTANT shall submit, with each of the monthly status reports provided for under Section B.1.1 of this Schedule B, an invoice for fees earned in the performance of Basic Services and Additional Services during the subject billing month. B.2.4. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided and as set forth in the Amendment authorizing such Additional Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provision of Section 3.4.1 below. There shall be no overtime pay on Additional Services without the COUNTY's prior written approval. B.2.5, The compensation provided for under Section B.2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are due and payable. 3. SCHEDULE OF PAYMENTS B.3.1. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by the COUNTY. Page 20 of 32 PSA_CCNA Single Project Agreement 7017.010 Ver.3 B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "lathes" as untimely submitted_ Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT's letterhead and must include the Purchase Order Number and Project name and shall not be submitted mare than one time monthly. B.3.3, Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. B.3.4. Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for this Agreement or Additional Services, CONSULTANT shall be limited to a maximum markup of five percent (5%) on the fees and expenses associated with such subconsultants and subcontractors. B.3.41 Reimbursable Expenses must comply with §112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items. B.3.4.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. 13,3.4.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by the COUNTY. Such expenses, if approved by the COUNTY, may include coach airfare, standard accommodations and meals, all in accordance with §112.061, Fla. Stat. Further, such expenses, if approved by the COUNTY, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.4.1.3. Permit Fees required by the Project. B.3.4.1.4. Expense of overtime work requiring higher than regular rates approved in advance and in writing by the COUNTY. B.3.4.1,5. Expense of models for the County`s use. 8.3.4.1,6. Other items on request and approved in writing by the COUNTY. B.3.4.1.7. The CONSULTANT shall bear and pay all overhead and other expenses, except for authorized reimbursable expenses, incurred by CONSULTANT in the performance of the Services, Page 21 of 32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 OCAO 6,14.1.8. Records of Reimbursable Expenses shall be kept on a generally recognized accounting basis. 13,15. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring any reimbursable expenses, and absent such prior approval, no expenses incurred by CONSULTANT will be deemed to be a reimbursable expense. Page 22 of 32 PSA_CCNA Single Projw Agreement 2017.010 Ver.3 �'A(3 SCHEDULE B -- ATTACHMENT 1 CONSULTANT'S HOURLY RATE SCHEDULE Title Hourly Rate Principal $238 Project Manager $165 Engineer $136 Princi al/Senior Landsca a Architect $165 Senior Designer $128 Senior Technician $102 CADD Technician $95 Surveyor and Ma er $142 Survey Crew-2 man $152 The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added via an Amendment upon mutual agreement in advance and in writing by the parties. Far Gr,pt Funded Prolects, the above hourly rates are for purposes of providing estimate(s), as required by the grantor agency. Page 23 of 32 PSA_CCNA Single Project Agreement 2017,010 Ver 3 SCHEDULE C PROJECT MILESTONE SCHEDULE Task/Item Description Number gf Q&ndg QW for Completion of Tash fam Q& 9f Notice to Proceed fi i Preliminary Discovery (Alternatives) 60 1 Surveying 90 2 Geotechnical 120 3 Basis of Design Report (BODR) 150 4 Final Design 270 5 Public Involvement Continuous throughout the project 6 Permitting 300 7 Post -Design Services TBD TOTAL CALENDAR DAYS FOR PROJECT COMPLETION FROM NTP 2487 Page 24 of 32 PSA_CCNA Single Project Agreemerit 2017.010 Ver.3 SCHEDULED INSURANCE COVERAGE 1, The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self -insured retentions or deductibles under any of the below listed minimum required coverages, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self -insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be CONSULTANT's sole responsibility. 2. The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. 3. Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the COUNTY or as specified in this Agreement, whichever is longer. 4. Certificates of insurance acceptable to the COUNTY shall be flied with the COUNTY within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance policies required shall be provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall 'contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the COUNTY. CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or material change in coverages or limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve CONSULTANT of this requirement to provide notice, In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project. 6, The acceptance by the COUNTY of any Certificate of Insurance does not constitute approval or agreement by the COUNTY that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. 7, CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the COUNTY. Page 25 of 32 PSA_CCNA Single Project Agreement 2W 7.aIQ Ver.3 8. Should at any time the CONSULTANT not maintain the insurance coverages required herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand, the COUNTY has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Agreement. 9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and the COUNTY may terminate the Agreement for cause. 10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY. Required by this Agreement? ❑O Yes ❑ No Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability - The coverage must include Employers' Liability with a minimum limit of $1,000,000 for each accident, The insurance company shall waive all claims rights against the COUNTY and the policy shall be so endorsed. 11. United States Longshoreman's and Harbor Worker's Act coverage shall be maintained where applicable to the completion of the work. Required by this Agreement? ❑ Yes ■❑ No 12. Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Required by this Agreement? ❑ Yes F No 13. COMMERCIAL GENERAL LIABILITY. Required by this Agreement? F07 Yes ❑ No A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Page 26 of 32 PSA_CCNA Single Project Agreement2017.DIO Vera Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the following: Coverage shall have minimum limits of $1,000,000 _ Per Occurrence, $ 2,000,000 aggregate. B. The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part, The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self -insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self -insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. 14, Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. The insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 15. Watercraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not Tess than the Commercial General Liability limit shown in subparagraph (1) above if applicable to the completion of the Services under this Agreement. Required by this Agreement? ❑ Yes ❑■ No 16. Aircraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Required by this Agreement? ❑ Yes ❑■ No 17. AUTOMOBILE LIABILITY INSURANCE. Required by this Agreement? ■❑ Yes ❑ No Business Auto Liability., Coverage shall have minimum limits of $500,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non -Owned Vehicles and Employee Non -The ownership. Page 27 of 32 PSA_CCNA Single Project Agreement 2017.010 Ver.3 18. TECHNOLOGY ERRORS AND OMISSIONS INSURANCE. Required by this Agreement? ❑ Yes ❑■ No Technolocy Errors and Omissions Insurance: Coverage shall have minimum limits of $ Per Occurrence. 19. CYBER INSURANCE. Required by this Agreement? ❑ Yes FE-1 No Cvber Insurance: Coverage shall have minimum limits of $ Per Occurrence. 20. UMBRELLA LIABILITY. A. Umbrella Liability may be maintained as part of the liability insurance of the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverages required herein and shall include all coverages on a "following form" basis. B. The policy shall contain wording to the effect that, in the event of the exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. 21. PROFESSIONAL LIABILITY INSURANCE. Required by this Agreement? F Yes ❑ No A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its legal liab0ity for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under this insurance. Such insurance shall have limits of not less than $1,000,000 each claim and aggregate. B. Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT, Deductible amounts are subject to the approval of the COUNTY. C. The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the COUNTY. D. The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to the COUNTY of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or material change in coverages or limits received by CONSULTANT from its insurer. In the event Page 26 or32 PSA_CCNA Single Project Agreement 201 7.010 Ver.] of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by the COUNTY. 22. VALUABLE PAPERS INSURANCE. In the sole discretion of the COUNTY, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. 23. PROJECT PROFESSIONAL LIABILITY. A, If the COUNTY notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with the COUNTY and the COUNTY's insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT's professional liability policy. If no credit is available from CONSULTANT's current professional policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to the COUNTY. Should no credit accrue to the COUNTY, the COUNTY and CONSULTANT, agree to negotiate in good faith a credit on behalf of the COUNTY for the provision of project -specific professional liability insurance policy in consideration for a reduction in CONSULTANT's self -insured retention and the risk of uninsured or underinsured consultants. B. The CONSULTANT agrees to provide the following information when requested by the COUNTY or the COUNTY's Project Manager, 1. The date the professional liability insurance renews. 2. Current policy limits. 3. Current deductibles/self-insured retention. 4. Current underwriter. 5. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. 6. Cost of professional insurance as a percent of revenue. 7. Affirmation that the design firm will complete a timely project errors and omissions application. C. If the COUNTY elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and the COUNTY will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds, END OF SCHEDULE D Wage 29 or32 PSA_UNA Sing) eProjeel Agreement2017AEOVer.3 SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE In compliance with the Consultants' Competitive Negotiation Act, Section 287.065, Florida Statutes, A noli Barber & Brundage, Inc. (company's name) hereby certifies that wages, rates and other factual unit costs supporting the compensation for the services of the CONSULTANT to be provided under the Professional Services Agreement, concerning " Design Sgalces " roject is accurate, complete and current as of the time of contracting. 1 BY: {'` Dominick J. A ico, P.E. TITLE; President DATE; _ IC 11b A6z0 Page 30 a f 32 YSA_CCNA Single Project Agreemenl2017.010 Ver.3 D SCHEDULE F KEY PERSONNEL Name Personnel Category Percentage of Time Dominick J. Amico PE Principal 5% James A. Carr PE Principal 5% Edward F. Tryka, III PE Project Manager 17% Engineer 23% Brent C. Guillot RLA Principal/Senior Landscape Architect 2% Senior Designer 11% Senior Tech 26% CADD Tech 2% Wayne A noli PSM Surveyor & Mapper 3% George Hackney, PSM Surveyor & Mapper 3% Survey Crew 2-man 6% Page 31 of 32 PSA_CCNA Single Project Agreement 2M 010 Ver.3 SCHEDULE G Other: Federal Grant Contract Provisions (Description) ❑■ following this page (pages I through 10 ) ❑ this schedule is not applicable Page 32 of32 PSA_CCNA Single Project Agreemenl2017,010 Ver.3 EYH. 1.A FEDERAL GRANT CONTRACT PROVISIONS COLLIER COUNTY FEMA - HAZARD MITIGATION GRANT PROGRAM (HMGP) i CONTRACT PROVISIONS CF pA 07,039 ....... ..... .. . This project activity is funded In whale or in part by the Federal Government, or an Agency thereof. Federal Law requires that the Applicant's contracts relating to the project include certain provisions. The supplemental conditions contained in this section are Intended to cooperate with, to supplement, and to modify the general conditions and other specifications, In cases of disagreement with any other section of this contract, the Supplemental Conditions shall govern. Per uniform requirements of federal awards (2 CFR Part 2Dfl.23) the definition of CONTRACTOR is an entity that receives a contract (including a purchase order). Compliance with Federal Law, Regulations and Executive Orders: The Sub -Recipient (County) agrees to lnclWe in the subcontract that (1) the subcontractor is bound by the terms of the Federally -Funded Subaward and Grant Agreement, (ii) the subcontractor is bound by all applicable state and Federal laws and regulations, and (N) the subcontractor shall hold the Division and Sub -Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. Specifically, the Contractor shall be responsible for being knowledgeable and performing any and all services under this contract in accordance with the following goveming regulations along with any and all other relevant Federal. State, and local laws, regulations, codes and ordinances: The Hazard MI%Btton Grant Program (HMGP) is generally, governed by the following statutes and regulations: 0 2 C.F.R. Part 200 uniform AdminisiraVve Requirements, Cost Principles, and Audit Requirements for Federal Awards 0 44 C.F.R. Parts 7, 9,10,13,14,17,18, 25, 206, 220, and 221, and any other applicable FEMA policy memoranda and guidance document; o The Robert T. Stafford Disaster Relief and Emergency Assistance Act o State of Florida Administrative Plan for the Hazard Mitigation Grant Program FCP - 1 EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS APPLICABLE FEMA HMGP PROVISIONS Atcess to Records: t1) The contractor agrees to provide the County, the FEMA Administrator, the Comptroller General of the United States, or any of their authorized representative's access to any books, documents, papers, and records of the Contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts, and transcriptions. (2) The Contractor agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. (3) The contractor agrees to provide the FEMA Administrator or his authorized representatives' access to construction or other work sites pertaining to the work being completed under the contract. (4) In compliance with the Disaster Recovery Act of 2018, Collier County and the Contractor acknowledge and agree that no language to this contract Is intended to prohibit audits or Internal reviews by the FEMA Administrator or the Comptroller General of the United States. Administrative, Contractual, or Legal Remedies: Applies to contracts greater than the simplified acquisition threshold, currently set of $250,000. Unless otherwise provided in this contract, all claims, counter-daims, disputes and other matters in question between the local government and the contractor, arising out of or relating to this contract, or the breach of it, will be decided by arbitration. If the parties mutually agree, or In a Florida court of competent jurisdiction. Americans with disabilities Act: The contractor agrees to comply with the Americans with Disabilities Act (Public Law 101-336, 42 U.S.C. Section 12101 sit s9Z), which prohibits discrimination by public and private entities on the basis of dlsablllty In employment, public accommodations, transportation. State and local government services, and telecommunications, Buy America Act; Applies to subcontracts. The contractor agrees to comply with 41 U.S.C. 10a, All unmanufactured and manufactured articles, materials and supplies which are acquired for public use must have been produced in the United States as required under 41 U.S.C. 10a, unless it would not be in the public interest or unreasonable in cost, Byrd Anti -Lobbying Amendment: Applies to contracts 4100,000, Contractors who apply or bid for an award of $100,000 or more shall file the required certi€cation. Each tier certifies to the tier above that It wlil not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant, or any other award covered by 31 U.S.C. § 1352. Each tier shall also disclose any lobbying with non -Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the recipient. Changes: See Standard Purchase Order Terms and Conditions. Clean Air Act and the Federal Water Pollution Control Act; Applies io all contracts and subcontracts 4150,000. Contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act (42 U.S.C. 7401-7671q) and the Federal Water Pollution Control Act as amended (33 U.S.C, 1251-1387) and will report vloiations to FEMA and the Regional Office of the Environmental Protection Agency (EPA). Compliance with Federal Law, Regulations, and Executive Orders: This is an acknowledgement that FEMA financial assistance will be used to fund the contract only. The contractor will comply will all applicable federal law, regulations, executive orders, FEMA policies, procedures, and directives. Contract Work Hours and Safety Standards: Applies to Contracts 3-$100, 000 and involves the employment of mechanics or laborers. 29 C.F,R. § 5.5(b) (1) Qverttme requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek. FCP - 2 FXH, 1.A FEDERAL GRANT CONTRACT PROVISIONS (2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1) of this section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages, In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual labarer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph ( 1) of this section, in the sum of $1 D for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1) of this section. (3) Withholding for unpaid wages and liquidated damages. The (write in the name of the Federal agency or the loan or grant recipient) shall upon Its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withhold, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally -assisted contract subject to the Contract Work Hours and Safety Standards Act, which Is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided In the clause set forth In paragraph (2) of this section. (4) Subcontracts. The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph (1) through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (1) through (4) of this section." Contracting with Small and Minority Businesses, Women's Business Enterprises, and Labor Surplus Area Firms: 1200.321 (a) The Solicitor must take all necessary affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whengvQr possible. (b) Affirmative steps must include: (1) Placing qualified small and minority businesses and women's business enterprises on solicitation lists; (2) Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; (3) Dividing total requirements, whsn_economically feasible, Into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; (4) Establishing delivery schedules, r r irem nt ernrits, wNch encourage participaill by small and minority businesses, and women's business enterprises; (5) Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce; and (6) Requiring the prime contractor, if subcontracts are to be let, to take the affirmative steps kstad In paragraphs (1) through (5) of this section. b, The requirement outlined +n subparagraph a. above, sometimes referred to as "socioeconomic contracting," does not impose an obligation to set aside either the solicitation or award of a Contract to these types of firms. Rather, the requirement only Imposes an obligation to carry out and document the six affirmative steps identified above, c. The "socioeconomic contracting" requirement outlines the affirmative steps that the Sub -Recipient must take; the requirements do not preclude the Sub -Recipient from undertaking additional steps to involve small and minority businesses and women's bus€Hass enterprises, d. The requirement to divide total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises, does not authorize the Sub -Recipient to break a single project down into smaller components In order le circumvent the micro -purchase or small purchase thresholds so as to utilize streamlined acquisition procedures (e.g. "project splitting"). FCP-3 EXH. I.A FEDERAL GRANT CONTRACT PROVISIONS Copetartd "Anti-Kicklaack" Act: a. Contractor. The contractor shalf comply with 18 U,S.C. § 874. 40 U.S.C. § 3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are Incorporated by reference into this contract. b. $ubcontracts. The contractor or subcontractor shall insert in any subcontracts the clause above and such other clauses as FEMA may by appropriate instructions require, and also a clause requiring the subcontractors to Include these clauses in any louver tier subcontracis. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all of these contract clauses. c, Breach. A breach of the contract clauses above may be grounds for termination of the contract, and for debarment as provided in 29 C.F.R. § 5,12. Debarment and Suspension, (1) This contract Is a covered transaction for purposes of 2 C.F.R. pt. 180 and 2 C.F.R_ pt. 3000. As such the contractor is required to verify that none of the contractor, its principals (defined at 2 C.F.R. § 180.996t, or its affiliates (defined at 2 C.F.R. § 180.905) are excluded (defined at 2 C.F.R. § 160.940) or disqualified (defined at 2 C,F,R. § 180.935). (2) The contractor must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C and must include a requirement to comply with these regulations In any lower tier covered transaction It enters into. (3) This certificallon is a material representation of fact relied upon by the County, if it is later determined that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C,F,R. pt. 3000, subpart C, in addition to remedies avaitable to the County, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. (4) The bidder or proposer agrees to comply with the requirements of 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in Its lower tier covered transactions, DNS Beal, Logo, and Flags; The contractor shall not use the DHS seel(s), logos, crests, or reproductions of flags or likenesses of DH8 agency officials without specific FEMA pte- approval. This is an acknowledgement that FEMA finsndal assistance will be used to fund all or a portion of the contract. The contractor will comply with all applicable Federal law, reguiations, executive orders, FEMA policies, procedures, and directives, Energy Efficiency Standards: The contractor agrees to comply with mandatory standards and policies relating to energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy and Conservation Act (42 U.S,C. 6201). Equal Employment Opportunity Clause (§60-1,4); Except as otherwise provided under 41 C.F.R. Part 60, all contrasts thilt meal the definition,-gf^fgderally assistog_construction nCo tract" In 41 C.F.R. § 60-1.3 must include the equal opportunity clause provided under 41 C.F.R. § 60- 1.4(b). During the performance of this contract, the contractor agrees as follows; The contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender Identity, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that emptoyees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall Include, but not be limited to the following. Empioyment, upgrading, dernotlon, or transfer, recruitment, or recruitment advertising; layoff or termination; rates of pay or other forms of compensatlon; and selection for training, including apprenticeship. The contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. II. The contractor will, In all solicitations or advertisements for employees placed by or on behalf of the contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender Identity, or national origin. Ill. The contractor will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the oompansatton of the employee or applicant or another employee or applicant This provision shah not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure Is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, MP-4 '¢dot ETCH. 1.A FEDERAL GRANT CONTRACT PROV1SJONS hearing, or action, Including an investigation conducted by the employer, or is consistent with the contractor's legai duty to furnish information. IV. The contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under section 202 of Executive Order 11246 of September 24, 1985, and shalt post copies of the notice In conspicuous places available to employees and applicants for employment- V. The contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. VI. The contractor will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records,, and accounts by the contracting agency and the Secretary of Labor for purposes of Investigation to ascertain compliance with such rules, regulations, and orders. VIi. In the event of the contractor's non-compliance with the nondiscrimination clauses of this contract or wlth any of such rules, regulations, or orders, 11% contract may tie canceled, terminated or suspended in whole or in part and the contractor may be declared Ineligible for further Government contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided In Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. Vill, The contractor will include the provisions of paragraphs (1) through (8) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24. 1%5, so that such provisions will be binding upon each subcontractor or vendor. The contractor vhII take such action with respect to any subcontract or purchase order as may be directed by the Secretary of Labor as a means of enforcing such provisions Including sanctions for noncompliance: Provided, however, that in the event the contractor becomes Involved In, or is threatened with, litigation with a subcontractor or vandor as a result of such direction, the contractor may request the United States to enter into such litigation to protect the interests of the United States. No Obligation by Federal Government: The Federal Government is not a party to this contract and Is not subject to any obligations or liabillties to the non -Federal entity, contractor, or any other party pertaining to any matter resulting from the contract. Procurement of Recovered Materials (§200.322): Bgguiremerlts: The requirements of Section 6002 include procuring only Items designated in guidelines of the EPA at 40 C.F.R. Part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired by the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and estabtlshing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. (1) In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA deslgnated items unless the product cannot be acquired (i) Competitively within a timeframe providing for compliance with the contract performance schedule; (It) Meeting contract performance requirements; or (ill) At a reasonable price. (2) Information about this requirement Is available at EPA's Comprehensive Procurement Guidelines web site, .`_ ?t _,;a,;t+v _r,; f:r, n ;,rni r._,:<=?_.. J`-Lsi_} —`c r uir ; cpIj-j r, rU n (3) The Contractor also agrees to comply with all other applicable requirements of Section 6002 of the Solid Waste Disposal Act. Program Fraud and False or Fraudulent Statements or Related Acts: The contractor acknowledges that 31 U.S.G. Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the contractor's actions pertaining to this contract. Reporting: The contractor will provide any information required to campty with the grantor agency requirements and regulations pertaining to reporting. It is important that the contractor is aware of the reporting requirements of the County, as the Federal or State granting agency may require the contractor to provide certain information, documentation, and other reporting In orderto satisfy reporting requirements to the granting agency. FOP-5 EXH. 1.A FEDERAL GRANT CONTRACT PROVISIONS Termination for Cause and Convenience: Applies to allconfracts >$10,000. Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenlence with a thirty (30) day written notice. The County shall be note judge of non- performance. In the event that the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the Agreement Amount earned through the data of termination, The Contractor shall not be entitled to any other or further recovery against the County, Including, but not limited to, any damages or any anticipated profit on portions of the services not performed. STATE PROVISIONS Convicted Vendor and Discriminatory Vendors List: Those who have been placed on the convicted vendor list following a conviction for a public entity crime or on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a pubic entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real properly to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with a public entity, and may not transact business with any public entity In excess of $25,000.00 for a period of 36 months from the date of being placed an the convicted vendor list or on the discriminatory vendor list, immigration and Natfonatity Act: The State of Florida will not intentionally award publicly -funded contracts to any contractor who knowingly employs unauthorized alien workers, constituting a violation of the employment provisions contained In 8 U.S.C. Section 1324a(s) (Section 274A(e) of the Immigration and Nationality Act ("INA")). The division shall consider the employment by any contractor of unauthorized aliens a violation of Section 274A(e) of the INA. Inspector General Cooperation,. The Parties agree to comply with Section 20,055(5), Florida Stabiles, for the inspector general to have access to any records, data and other information doomed necessary to carry out his or her duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5), Florida Statutes. Lobbying: No funds recebved pursuant to this Agreement may he expended for lobbying the Legislature, the judicial branch or any state agency. Public Records: The more receipt of public funds by a private entity, standing alone, is Insufficient to bring that entity within the ambit of the public record requirements. However, when a public entity delegates a public function to a private entity, the records generated by the private antlty's performance of that duty become public records. Thus, the nature and scope of the services provided by a private entity determine whether that entity Is acting on behalf of a public agency and is therefore subject to the requirements of Florida's Public Records Law, Record Retention: The contractor shall maintain and retain sufficient records dernonstraling Its compliance with the terms of the Agreement for a period of at least five (5) years after final payment to made and shall allow the County, FOEM, or its designee's access to such records upon request. FCP-6 ExHISIT I. IS FEDERAL_ CONTRACT PROVISIONS AND ASSURANCES Acknowledgement of Terms, Conditions, and Grant Clauses Certification If the vendor subcontracts any of the work required under this Agreement, a copy of the signed subcontract must be available to the Department for review and approval. The vendor agrees to include in the subcontract that (1) the subcontractor is bound by the terms of this Agreement, (ii) the subcontractor is bound by all applicable state and federal laws and regulations, and (iii) the subcontractor shall hold the Department and Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. The recipient shall document In the quarterly report the subcontractor's progress in performing its work under this agreement For each subcontract, the Recipient shall provide a written statement to the Department as to whether the subcontractor Is a minority vendor as defined in Section 288.703, Fla. Stat. On behalf of my firm, I acknowledge, the grant requirements identified in this document. Vend orlContractor Name A, noli, Barber & Brundage, Inc. Date �.n .. Authorized Signature=��`'?.'••-� r ,�ntcF Dominick J. Amic0l., President EXHIBIT LE - 1 EXHIBIT I FEDERAL. CONTRACT PROVISIONS AND ASSURANCES CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY and VOLUNTARY EXCLUSION Contractor Covered Transactions (1) The prospective subcontractor of the Sub -recipient, Collier County, certifies, by submission of this document, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency. (2) Where the Sub -recipient's subcontractor is unable to certify to the above statement, the prospective contract shall attach an explanation to this form, CONTRACTOR Agnoli, Barber & Brundaue, Inc. ! Signature Dominick 1, Armco, P.E., President _ Name and Title - 7400 Trail Boulevard, Suite 200 Street Address Naples, FL 34109 _ City, State, Zip t1-413-9991 DUNS Number Date Sub -Recipient Name: Collier County Board of County Commissioners DEM Contract Number, H0309 FEMA Project NumbeT: 4337-192-R EXHIBIT LB - 2 COLLIER COUNTY ANTICIPATED DISADVANTAGED, MINORITY, WOMEN OR VETERAN PARTICIPATION STATEMENT Status will be verified. Unverifable statuses will require the Vendor/Prime Contractor w either provide a revised statement or provide source documentation that validates a status. Contractor means an entity that receives a contract. VEN6OR/PRIME C7]NTRA6OR INFORMATION PRIME NAME PRIME FEID NUMBER CONTRACT DOLLAR AMOUNT Agnoli, Barber & Brundage, Inc. 59-22871.55 IS THE PRIME A FLORIDA-CER?IFIED DISADVANTAGED, VETERAN? Y IS THE ACTIVITY OF THI5 CONTRACT, MINORITY OR WOMEN BUSINESS ENTERPAISE DBEs Y O CONSTRUCTlON7 Y (OBE/MBEIWBE)? OR HAVE A SMALL DISADVANTAGED � BUSINESSBA CERTIFICATION FROM THE SMALL BUSINESS MBE? Y L':/ CONSULTATION? 0 N ADMINISTRATION? OR A SERVICE DISABLED VETERAN? WR0 Y OTHER? N SOB SA? Y N IS THIS SUBMISSION A REVISION? Y JIF YES, REVISION NUMBER ? + -- Ip IME HAS SUBCONTRACTOR OR SUPPLIER wH01;:5 A0ISADVANTAGED MINORITY,MIN B05INESSC0NGERN OR SERVICE DI5A9t ED VETERAN, PRIME IS TO CORMPLEIE DBE. MBE, WOE SUBCONTRACTOR OR SUPPLIER TYPE OF WORN OR ETHNICITY CODE PERCENT OF CONTRACT VET, SMBBA NAME SPECIALTY (See Belowl DOLLARS MBE Robau and Associates, LI.0 Engineer HA 15% WBE Quest Corporation of Public NMW 10% America. Inc. c. Information on C.'SECTION TO BE COMPLETED 13Y PRIME VCNDORjCONTRACTOR y NAME OF SUBMITTER DATE TITLE OF SUBMITTER Dominick J. Amico, P.E. 3/16/20 President EMAIL ADDRESS OF PRIME (SUIBM ITTERI TELEPHONE NUMBER FAX NUMBER amico�c,abbine.com (239) 597-3 l 1 l (239) 566-2203 NOTE: This information is used to track and report anticipated DBE or MIRE participation In federally -funded contracts. The anticipated DBE or MBE amount is voluntary and will not become part of the contractual terms. This form must be submitted at time of response to a solicitation. If and when awarded a County contract, the prime will he asked to update the information for the grant compliance files. YI �. _ d L N, LVY Black American BA Hispanic American HA Native American NA Subcont, Asian American SAA Asian -Pacific American APA Non -Minority WDmcn NMW Other: not of an other roue listed 0 D 'SECTION'TO ISE COMPLETED.:BY COLLIER COUNTY OR` ck � DEPAR7NEN7 NAVE COLLIER CONTRACT II tIFBIRFP or PO/PE4) I GRANT PROGRAMICONTRACT DATE EXHIBIT I.B- 3 EXHIBIT I FEDERAL CONTRACT PROVISIONS AND ASSURANCES LOBBYING CERTIFICATION T bi Itt d with each bid or offer excaedin 100 hilt} The undersigned [Contractor] certifies, to the best of his or her knowledge, that: 1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for Influencing or attempting to Influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. 2, if any funds other than Federal appropriated funds have been paid or will be paid to any person for Influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress In connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form- LLL, 'Disclosure Form to Report Lobbying,' In accordance with its instructions. 3. The undersigned shall require that the language of this certification be included In the award documents for at[ subawards at all tiers (including subcontracts, subgrants, and contracts under grants, loans, and cooperative agreements) and that all subrecipients shall certify and disclose accordingly, This certification Is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification Is a prerequisite for making or entering into this transaction imposed by 31, U.S.C. § 1352 (as amended by the Lobbying Disclosure Act of 1995). Any person who falls to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The Contractor certlfles or affirms the truthfulness and accuracy of each statement of Its certification and disclosure, If any. In addition, the Contractor understands and agrees that the provisions of 31 U,S.C. § 3801 et seq., apply to this certification and d[sclosure, If any. Agnoli, Barber & Brundage, Inc. Contractor (Firm Name) �f Signature of C ' ractoes Authorized Official Dominick J. Armco, P,E., President _ Name and Title of Contractor's Authorized Official Data EXHIBIT 1.8 - 4 A O°° (NM70DYYYY} CERTIFICATE OF LIABILITY INSURANCE IJATE 10M fi12020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER($), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT; If the certificate holder Is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In Ileu of such endorserrfent(s). PRODUR B awn & Brown Of Florida, Inc. NAM : ° Kristen KozlDw AH°"E 6611 Orion Blvd Suite 200 . 2392132CI1 FAX ou Myers Fort M FL 34112 EL — — — — y DDMAIEss_kkozlow@b4swfla.cam NSUAED Agnoli, Barber & Brundage Inc. 740G Trail Blvd Suite 200 Naples FL 34108 COVFRAnPA rlFdTiclrwrc 161![na120o.—...... and ERAGE _ NAIC p Lid. 11000 29424 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW I LAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY RSOUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. 1NSR DDL SU9R TYPE POLICY EFF MFYLTR OLCYNUMBER MM7 01YYYY MDW ---""- LIMITS A X COMMERCIAL GENERALLIABILfTY Y Y 121513MVLIEIS 51V2D20 5ftf2021 EACH OCCURRENCE S 1.000,000 CLAIMS -MADE OCCUR - _ PREMl3HS Ee Hence S 1,0D0,G60 ' $ 101000 MED EXP (Any one erson) $ 1.000,000 PERSONAL S ADV INJURY GEN'L AGGREGATE LIMIT APPLIES PER: S 2,000,000 GENERAL AGGREGATE 52,000,00¢ POLICY PE� LOG PRODUCTS, GOMPfOPAGG $2,000,000 OTHER: EmployeeBeneryta R AA�U--TOM661LELIABILITY Y Y 21UECDF2079 571?2420 5l112021 EQMHICNEDt INGLELIMlT $1,000,000 l X 1 ANY AUTO OWNED SCHEDULED 1! on BODILY INJURY IPer Pars } $ J� AUTOS ONLY AUTOS { 9oDILY INJURY filer accli nl) b X HIRED X NON -OWNED AUTOS ONLY AUTOS ONLY PROPEPROPERR-iYDAMAGH Y _ $ A X UMBRELLALIAe X OCCUR Y Y 21SOVVL1515 5?112020 5/112021 EACH Or $2.000,00_0 EXCESS LIAR CLAIMS -MADE _ AGGREGATE _ $2,000,000 DED x RETENTIONS $ C WORKERS COMPENSATION AND EMPLOYERS' LIABILITY .r Y 21VVBCAGOV2P 511/2020 5/1/2021 X 1 PER OTH• TATUTE ERANYPRO 114 OFFICER EM13E 1 EXCLUERlEXEC UTFVE N OFFICERIMEM6ERElCCLUbE07 NIA i E.L. E.L. EACH ACCIDENT _ $ 1,000.000 _ E.L. DISEASE - EA EMPLOYEE $ 1,000,000 (MandaIn NHI If 9es, tlescrespibe under E.L. DISEASE -POLICY LIMIT DESCRIPTION OF OPERATIONS below I $1,000,40D C E Prolasslonsl Liability Employment Practices Liability JES0000033 5/1/2020 511?2d21 Eat G?a,m 2,000.000 C346633763004 511/2020 511 /2021 Each Claim 1 ,000,000 DESCRIPTION OF OPERATIONS ? LOCATIONS f VEHICLES (ACORD Ial. Additional Remarks Schodalo, may be Attached If more space fa required) Engineering, Planning, Surveying & Landscape Architecture Firm Certificate holders are included as additional insured with regards to General Liability Coverage on a Pnmary & Nan -Contributory Basis including Ongoing and Completed Operations per from SS0008 0405, Generat Liability Waiver of Subrogation in favor of certificate holder when agreed in written contract per form $S0008 0405. Certificate holders are included as additional insured & Waiver of Subrogation in favor of certificate holder with regards to Auto Liability when agreed in written contract per form HA991 fi 0312. Waiver of Subrogation in favor of certificate holder when agreed in written contract per form WC000313. Ulribralla is follow form. 30 Days Notice of Cancellation, except for 10 days for Nonpayment. See Attached.._ Collier County Board of County Commissioners 3295 Tamiaml Trail E. Naples FL 34112 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORISED ©1988-2015 ACORD CORPORATION. All rlehtR rasatvad ACORD 25 (2016103) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER lD: 349910 LOC #t AC4ORa ADDITIONAL REMARKS SCHEDULE Page 1 of t AGENCY NAMED INSVRED Brown & Brown Of Florida, Inc. Agnoli, Barber & Brundage Inc. PQwcr NUMSER 7400 Trail Blvd Suite 200 Naples FL 34106 CARRIER NAIC CQDE EFFECTIVE QATE; The ACORD name and logo are registered marks of ACORD