Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
#20-7763 (R2T, Inc.)
CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with R2T, Inc. ("Contractor") of 580 W. Crossville Road, Suites 101-102, Roswell, GA 30075, a Corporation, authorized to do business in the State of Florida, to perform all work ("Work") in connection with NCWRF Effluent Filters No. 2 & 3 Equipment Replacement, Invitation to Bid No. 20-7763 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Collier County Engineering & Project Management Division the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount"), in accordance with the terms of this Agreement: Two Million Seven Hundred Fifty-Two Thousand Six Hundred Twenty-Nine Dollars ($2,752,629.00). Section 4. Bonds. A. If applicable, the Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit B-1 and B-2, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www.fms.treas.gov/c570/c570.html#certified. Should the Contract Amount be less Construction Services Agreement:Revised 072118(v6) C141 than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall,within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liquidated Damages. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The "Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within three hundred five (305)calendar days from the Commencement Date(herein "Contract Time"). The date of Substantial Completion of the Work(or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work(or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within sixty (60) calendar days after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase"Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, Two Thousand Seven Hundred Twelve Dollars ($2,712.00) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion. The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty,which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday , Construction Services Agreement:Revised 072118(v6) C' or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non-delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed upon, attached hereto and made a part of this Agreement for Solicitation 20-7763 "NCWRF Effluent Filters No. 2 & 3 Equipment Replacement". Exhibit A-1: Contractor's Bid Schedule Exhibit A-2: Contractor's Bid Submittal Forms and Addendums Exhibit A-3: Contractor's List of Key Personnel Exhibit B-1: Payment Bond Forms n Not Applicable Exhibit B-2: Performance Bond Forms n Not Applicable Exhibit B-3: Insurance Requirements Exhibit C: Release and Affidavit Form Exhibit D: Contractor Application for Payment Form 3 CA( Construction Services Agreement:Revised 072118(v6) Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions ❑ Applicable ® Not Applicable The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 20-7763 "NCWRF Effluent Filters No. 2 & 3 Equipment Replacement". The complete contract documents, including Addendum with attachments, are available on the County's on-line bidding system: https://www.bidsync.com/bidsync-cas/, which the parties agree comprise the final integrated agreement executed by the parties. Sections corresponding to any checked box ( ® ) expressly apply to the terms of this Agreement and are available through the County's on-line bidding. ®Exhibit J: Technical Specifications nExhibit K: Permits ❑Exhibit L: Standard Details ®Exhibit M: Plans and Specifications prepared by Collier County Engineering & Project Management Division Exhibit N: Environmental Health and Safety Requirements for Construction Projects Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, FL do Public Utilities Engineering & Project Management Division 3339 Tamiami Trail E, Suite 303 Naples, Florida 34112 Attn: Wayne Karlovich, P.E., Senior Project Manager Phone: (239) 252-5372 Email: Wayne.Karlovich(a�colliercountyfl.gov B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: R2T, Inc. 500 Village Square Crossing, Suite 202 Palm Beach Gardens, FL 33410 Attn: George Ajy, Vice President Phone: (561) 775-0009 Email: George.aivCa�r2tinc.com C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. 4 Construction Services Agreement:Revised 072118(v6) C A9 Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreem ent. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. 5 Construction Services Agreement:Revised 072118(v6) CA(, Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. **** CAO 6 Construction Services Agreement:Revised 072118(v6) IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s) indicated below. CONTRACTOR: T WITNESSES . R2T, Inc. ir: (Y______ItLiNiP 44- FIRST WITNESS i -kJIM - 1 1 2ES 11,Ct•rBy: Pint Na 17/•ZDZa Print Na e and Titl Date ITNESS I ari iu0a Prin ame Date: .4 . 2,0 2 Q ATTEST: OWNER: Crystal K. Kinzel, Clerk of Courts BOARD OF COUNTY COMMISSIONERS & Comptroller OF COLLIER COUNTY FLORIDA B . \. BY: Ze.:.ef,ge.11°°4— Attest as-to Chairrhan'S Burt L. Saunders, Chairman signature only. Appr as to Form and Legality: p;�'A`�P*County Attorney } Print Name 7 ''ar, Construction Services Agreement:Revised 072118(v6) t EXHIBIT A-1: CONTRACTOR'S BID SCHEDULE (FOLLOWING THIS PAGE) 8 Construction Services Agreement:Revised 072118(v6) BID SCHEDULE COLLIER COUNTY SOLICITATION NO.20-7763 NCWRF Effluent Filters Nos. 2 &3 Equipment Replacement NOUTH COUNTY WATER RECLAMATION FACILITY(NCWRF) COLLIER COUNTY PUBLIC UTILITIES DEPARTMENT-EPMD PROJECT#70148.10.2 Item No. Description Unit Label Quantity Cost Per Unit Total 1 Mobilization/Demobilization(Not to Lump Sum 1 $100,000.00 $100,000.00 Exceed 10%of Total of Items 1-10) 2 Demolition of Filter Set No.2 Lump Sum 1 $92,105.00 $92,105.00 3 Filter Set No.2,Equipment&Material Lump Sum 1 $1,001,875.00 $1,001,875.00 4 Filter Set No. 2, Installation Lump Sum 1 $110,428.00 $110,428.00 5 Demolition of Filter Set No.3 Lump Sum 1 $92,105.00 $92,105.00 6 Filter Set No.3,Equipment&Material Lump Sum 1 $1,001,875.00 $1,001,875.00 7 Filter Set No.3, Installation Lump Sum 1 $110,428.00 $110,428.00 8 Filter Effluent Gates Equipment& Lump Sum 1 $76,100.00 $76,100.00 Material 9 Filter Effluent Gate Installation Lump Sum 1 $39,990.00 $39,990.00 10 Electrical Work Lump Sum 1 $27,723.00 $27,723.00 VWI ICI S HIIVWdIILC'IVI VWI ICI J U7C dJ Directed.This Allowance will be used only at the Owner's direction to accomplish work due to unforeseen conditions and/or as directed by the Owner.Inclusion of the Allowance as part of the Contract Price is not a 11 guarantee that the Contractor will be T&M 1 $100,000.00 $100,000.00 paid any portion or the full amount of the Allowance. Expenditures of Owners Allowance will be made through Change Order with proper documentation of Time and Materials supporting the change. TOTAL PRICE FOR ITEMS 1 THROUGH 11 $2,752,629.00 Submitted By: R2T, Inc. (Contractor Name) 0 EXHIBIT A-2: CONTRACTOR'S BID SUBMITTAL FORMS AND ADDENDUM (FOLLOWING THIS PAGE) 9 Construction Services Agreement:Revised 072118(v6) it Co Trier County Email: Barbara.Lance@colliercountyfl.gov Administrative Services Division Telephone: 239.252.8998 Procurement Services ADDENDUM#1 Date: May 14,2020 From: Barbara Lance,Procurement Strategist To: Interested Bidders Subject: Addendum# 1 —20-7763 NCWRF Effluent Filters Nos.2&3 Equipment Replacement This Addendum has been issued for the following items identifying clarifications,changes, deletions, and/or additions to the scope of work, solicitation documents and/or bid schedule for the above referenced solicitation: CHANGE 1: The"Bid Opening"scheduled for June 10,2020 @ 3:00 pm will no longer be held via lie Conferenee--B-r-ire and will take place "in person"at the below location: Procurement Services Division Conference Room A 3295 Tamiami Trail East,Bldg. C-2 Naples,FL 34112 Per the CDC Guidelines: • Social Distancing guidelines shall be applicable—persons 6 feet apart • Everyone shall wear a cloth face cover/mask If you require additional information please post a question on our Bid Sync(www.bidsync.com)bidding platform under the solicitation for this project. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6/5/2020 (Sig e) Date R2T,Inc. (Name of Firm) 0 Co ier .C out<aty Email: Barbara.Lance@colliercountyfl.gov u. Tele hone: 239.252.8998 �,ctrninistra4ve Services Division p Procurement Serves ADDENDUM#2 Date: May 15,2020 From: Barbara Lance,Procurement Strategist To: Interested Bidders Subject: Addendum#2—20-7763 NCWRF Effluent Filters Nos.2&3 Equipment Replacement This Addendum has been issued for the following items identifying clarifications,changes,deletions, and/or additions to the scope of work,solicitation documents and/or bid schedule for the above referenced solicitation: CHANGE 1: The"Pre-Bid Meeting"scheduled for May 27,2020 @ 11:00 am will no longer be held via Phone Conference Bridge and will take place "in person"at the below location: Procurement Services Division Conference Room A 3295 Tamiami Trail East,Bldg.C-2 Naples,FL 34112 ***A non-mandatory site visit will immediately follow the Pre-Bid Meeting at the project site: NCWRF, 10500 Goodlette Frank Road North,Naples,FL 34109. Per the CDC Guidelines: • Social Distancing guidelines shall be applicable—persons 6 feet apart • Everyone shall wear a cloth face cover/mask If you require additional information please post a question on our Bid Sync(www.bidsync.com)bidding platform under the solicitation for this project. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. ., - . + 6/5/2020 e(Sig , ) 4 Date R2T,Inc. (Name of Firm) Colter County Email: Barbara.Lance@colliercountyfl.gov Administrative Services Division Telephone: 239.252.8998 Procurement Services ADDENDUM#3 Date: May 28,2020 From: Barbara Lance,Procurement Strategist To: Interested Bidders Subject: Addendum#3—20-7763 NCWRF Effluent Filters Nos.2&3 Equipment Replacement This Addendum has been issued for the following items identifying clarifications,changes,deletions, and/or additions to the scope of work, solicitation documents and/or bid schedule for the above referenced solicitation: ADDITION: The Minutes and Sign-in sheet from the May 27,2020 Pre-Bid Meeting have been posted to BidSync: 20-7763 Pre-Bid Meeting Minutes 20-7763 Pre-Bid Meeting Sign-In Sheet If you require additional information please post a question on our Bid Sync(www.bidsync.com)bidding platform under the solicitation for this project. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. --" - 6/5/2020 (Si ture) Date R2T,Inc. (Name of Firm) Co ler Comity Email: Barbara.Lance@colliercountyfl.gov Adrninistrabve Services Division Telephone: 239.252.8998 Procurement Services ADDENDUM#4 Date: June 1,2020 From: Barbara Lance,Procurement Strategist To: Interested Bidders Subject: Addendum#4—20-7763 NCWRF Effluent Filters Nos.2&3 Equipment Replacement This Addendum has been issued for the following items identifying clarifications,changes, deletions, and/or additions to the scope of work,solicitation documents and/or bid schedule for the above referenced solicitation: CHANGE 1: The"Question/Answer period"has been extended from May 29,2020 @ 5:00 pm to: June 9,2020 @ 5:00 pm CHANGE 2: The"Bid End Date" has been extended from June 10, 2020 @ 3:00 pm to: June 16,2020 @ 3:00 pm If you require additional information please post a question on our Bid Sync(www.bidsync.com)bidding platform under the solicitation for this project. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6/5/2020 (Sig ure) Date R2T,Inc. (Name of Firm) S Cam® ter C mvity Email: Barbara.Lance@colliercountyfl.gov Administrative Services Division Telephone: 239.252.8998 Frocue rent Services ADDENDUM#5 Date: June 5,2020 From: Barbara Lance,Procurement Strategist To: Interested Bidders Subject: Addendum#5—20-7763 NCWRF Effluent Filters Nos.2&3 Equipment Replacement This Addendum has been issued for the following items identifying clarifications,changes,deletions, and/or additions to the scope of work,solicitation documents and/or bid schedule for the above referenced solicitation: CHANGE 1: Reference: 20-7763 Section 01600_Revised_Addendum 5 20-7763 Section 01650N Revised Addendum 5 Specification Section 01600—MATERIAL AND EQUIPMENT Replace Specification Section 01600 with the attached Section 01600—Revised (8 pages). Specification Section 01650—STARTING OF SYSTEMS Replace Specification Section 01650 with the attached Section 01605—Revised (4 pages). Specification Section 11366—TRAVELING BRIDGE FILTER Paragraph 2.3 L.: Delete the following from this Paragraph: "The pumps shall be painted with a minimum of 2-coats of approved epoxy paint sufficient to protect the coated surface from extended exposure to water with a concentration of 10 mg/L of chlorine." Paragraph 2.4 A.: Revise the second to the last sentence of this paragraph to read as follows: "The PLC shall be Allen-Bradley CompactLogix 1769-L33ER with Ethernet port.No substitutions shall be allowed." Paragraph 2.4 C.: Revise this paragraph to read as follows: C. Provide an Allen-Bradley 1783-BMSO6SL Stratix 5700 managed Ethernet Switch with fiber module to convert the 4-strand multimode fiber optic festoon cable to copper for connection to the PLC. Paragraph 2.4 Q.: Revise this paragraph to read as follows: Q. A new festooning system shall be provided for electrical and fiber optic signal cable connections to/from the main control panel mounted on the bridge to a new contractor provided power disconnect switch and from a new Owner provided fiber optic termination cabinet. Primary components of the festooning system shall include; nylon cable trolleys, turnbuckle and stainless steel wire rope for festooning suspension. Flat, PVC coated power cables shall be provided, sized in accordance with the National Electric Code. Connectors matching the cross-section contour of the flat cables shall be used to provide a closure at the cable entrance in the main panel, disconnect and fiber termination cabinet. A UV resistant strand multimode fiber optic festooned cable will be 1 cA0 run from the filter control panel to an Ethernet junction box with a patch connector mounted on the end of the filter. Fiber optic cable shall be Owens Corning 0M4 50um multimode 006TSF-T4190D20 (loose tube, gel free, 50um multimode with 4.4 inch bending radius for installation and 1.5 inch bending radius for operation). The flat festooning cable will be used as a base to lay the fiber optic cable on in order to provide for a smooth festooning action. By laying the fiber optic cable and using tie wraps to hold it to the flat festooning cable, the cable will be more resistant to twisting and tangling from wind action because of its light weight. Paragraph 3.2 B.: Delete Paragraph 3.2 B. in its entirety. Paragraph 3.3 C.: Revise the first sentence of the paragraph to read as follows: "The manufacturer's representative shall provide 20 days of on-site services of a factory trained field technician during the installation of the first filter." Drawings Plan Page 1: Revise the identifier"NEW FIBERGLASS WASHWATER TROUGH"to read "EXISTING FIBERGLASS WASHWATER TROUGH TO BE REUSED" Plan Page 2: Revise the 8" spacing dimension of the New 4" Underdrain Lateral to be 12" Section A-A: Revise the identifier"NEW 4" PVC UNDERDRAIN LATERAL(90 REQ'D)"to read "NEW 4" PVC UNDERDRAIN LATERAL(FIELD VERIFY QUANTITY)" Section B-B: Revise the identifier"NEW FIBERGLASS W/W TROUGH"to read "EXISTING FIBERGLASS W/W TROUGH" Plan Page 7: Add the following to this drawing: NOTE: THIS DRAWING IS INTENDED TO SHOW THE LOCATION OF THE NEW SLIDE GATES G-3A-1, 2, 3,4. ANY OTHER CALLOUTS ON THIS PLAN ARE FROM RECORD DRAWINGS OF A PAST PROJECT AND ARE NOT REQUIREMENTS OF THE WORK IN THIS PROJECT. If you require additional information please post a question on our Bid Sync(www.bidsync.com)bidding platform under the solicitation for this project. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. `�-- - June 5,2020 (Signature) Date R2T, Inc. (Name of Firm) 2 Cater C014.14tY Email: Barbara.Lance@colliercountyfl.gov Administrative Services Dusan Telephone: 239.252.8998 Procurement Servk es ADDENDUM#6 Date: June 12,2020 From: Barbara Lance,Procurement Strategist To: Interested Bidders Subject: Addendum#6—20-7763 NCWRF Effluent Filters Nos.2&3 Equipment Replacement This Addendum has been issued for the following items identifying clarifications,changes,deletions, and/or additions to the scope of work,solicitation documents and/or bid schedule for the above referenced solicitation: CHANGE 1: Fact Sheet Under Contract Documents, Paragraph 3) Electrical Requirements: Add the following paragraph h) Owner will terminate fiber optic cable in Owner furnished fiber optic termination cabinet(s)and contractor furnished filter control panel(s). Specification Section 11366—TRAVELING BRIDGE FILTER Paragraph 2.4 B.: Revise this paragraph to read as follows: B. Owner will terminate fiber optic cabling in a Fiber Optic Termination Cabinet furnished by Others(Owner). Paragraph 2.4 Q.: Revise this paragraph to read as follows: Q. A new festooning system shall be provided for electrical and fiber optic signal cable connections to/from the main control panel mounted on the bridge to a new contractor provided power disconnect switch and from a new Owner provided fiber optic termination cabinet. Owner will perform final terminations of fiber optic cable in fiber optic termination cabinet(s) and main control panel(s). Primary components of the festooning system shall include; nylon cable trolleys, turnbuckle and stainless steel wire rope for festooning suspension. Flat,PVC coated power cables shall be provided, sized in accordance with the National Electric Code. Connectors matching the cross-section contour of the flat cables shall be used to provide a closure at the cable entrance in the main panel, disconnect and fiber termination cabinet. A UV resistant strand multimode fiber optic festooned cable will be run from the filter control panel to an Ethernet junction box with a patch connector mounted on the end of the filter. Fiber optic cable shall be Owens Corning 0M4 50um multimode 006TSF-T4190D20 (loose tube, gel free, 50um multimode with 4.4 inch bending radius for installation and 1.5 inch bending radius for operation). The flat festooning cable will be used as a base to lay the fiber optic cable on in order to provide for a smooth festooning action. By laying the fiber optic cable and using tie wraps to hold it to the flat festooning cable, the cable will be more resistant to twisting and tangling from wind action because of its light weight. 1 C1t0 If you require additional information please post a question on our Bid Sync(www.bidsync.com)bidding platform under the solicitation for this project. Please sign below and return a copy of this Addendum with your submittal for the above referenced solicitation. 6/15/2020 (Signature) Date R2T,Inc. (Name of Firm) 2 Q FORM 1-BID RESPONSE FORM BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY,FLORIDA NCWRF Effluent Filters No.2&3 Equipment Replacem ent BID NO.20-7763 Full Name of Bidder R2T,Inc. Main Business Address 580 W.Crossville Road,Suite 101,Roswell,GA 30075 Place of Business 500 Village Square Crossing,Suite 202,Palm Beach Gardens,FL 33410 Telephone No. 561-775-0009 Fax No. 561-775-0092 State Contractor's License# Underground Utility&Excavation #CUC1224943;General Contractor#CGC1511908 State of Florida Certificate of Authority Document Number F05000003590 Federal Tax Identification Number 20-2835149 DUNS# 798246919 CCR# Cage Code 4R9Z8 To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY,FLORIDA (hereinafter called the Owner) The undersigned,as Bidder declares that the only person or parties interested in this Bid as principals are those named herein, that this Bid is submitted without collusion with any other person, firm or corporation; that it has carefully examined the location of the proposed Work,the proposed form of Agreement and all other Contract Documents and Bonds,and the Contract Drawings and Specifications. Bidder proposes, and agrees if this Bid is accepted, Bidder will execute the Agreement included in the Bidding Documents, to provide all necessary machinery,tools, apparatus and other means of construction, including utility and transportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract, and to do all other things required of the Contractor by the Contract Documents,and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points,and in the case where further decimal points are inadvertently provided,rounding to two decimal points will be conducted by Procurement Services Division staff. Upon notification that its Bid has been awarded,the Successful Bidder will execute the Agreement form attached to the Bidding Documents within ten(10)calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents.The bid security attached is to become the property of the Owner in the event the Agreement,Insurance Certificates and Bonds are not executed and delivered to Owner within the time above set forth, as liquidated damages, for the delay and additional expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period. In the event of such failure, the total amount of Owner's damages, will be difficult, if not impossible,to definitely ascertain and quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it fails to execute and deliver the Agreement, Insurance Certificates, and Bonds as required hereunder. The Successful Bidder hereby expressly waives and relinquishes any right which it may have to seek to characterize the Construction Solicitation Doc rev 02-21-20 above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates,and Bonds in a timely manner. Upon receipt of the signed and approved agreement and Purchase Order,the undersigned proposes to commence work at the site within five(5)calendar days from the commencement date stipulated in the written Notice to Proceed unless the Project Manager, in writing, subsequently notifies the Contractor of a modified(later)commencement date. The undersigned further agrees to substantially complete all work covered by this Bid within three hundred and five (305)consecutive calendar days,computed by excluding the commencement date and including the last day of such period,and to be fully completed to the point of final acceptance by the Owner within sixty(60)consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. Acceptance and acknowledged by an Authorize Agent Signature: / Title: Vice President Date: 6/5/2020 Construction Solicitation Doc rev 02-21-201110 FORM 3-MATERIAL MANUFACTURERS THIS FORM MUST BE COMPLETED OR BID SHALL BE DEEMED NON-RESPONSIVE All Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this Bid specifications,including compliance with Florida Statute 255.20 to provide lumber,timber and other forest products produced and manufactured in the State of Florida as long as the price,fitness and quality are equal. Exceptions(when equals are acceptable) may be requested by completing the Material Manufacturer Exception List below. If an exception for a manufacturer and/or material is proposed and listed below and is not approved by Engineer/Proj ect Manager,Bidder shall furnish the manufacturer named in the specification.Acceptance of this form does not constitute acceptance of material proposed on this list. Complete and sign section A OR B. Section A(Acceptance of all manufactures and materials in Bid specifications) On behalf of my firm,I confirm that we will use all manufacturers and materials as specifically outlined in the Bid specifications. Company: R2T,Inc. Signature: �=~ a ,y�i Date: 6/5/2020 Section B(Exception requested to Bid specifications manufacturers and materials) EXCEPTION MATERIAL EXCEPTION MANUFACTURER 1. 2. 3. 4. 5. Please insert additional pages as necessary. Company: Signature: Date Construction Solicitation Doc rev 02-21-20 FORM 4-LIST OF MAJOR SUBCONTRACTORS THIS LIST MUST BE COMPLETED OR BID MAY BE DEEMED NON-RESPONSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories outlined in the requirements of the Bid specifications. The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the major categories listed herein are"qualified"(as defined in Ordinance 2017-08 and Section 15 of Instructions to Bidders)and meet all legal requirements applicable to and necessitated by the Contract Documents,including,but not limited to proper licenses, certifications, registrations and insurance coverage. The Owner reserves the right to disqualify any Bidder who includes non-compliant or non-qualified Subcontractors in its bid offer.Further,the Owner may direct the Successful Bidder to remove/replace any Subcontractor,at no additional cost to Owner,which is found to be non-compliant with this requirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents,the Successful Bidder shall identify all Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified as noted above. Major Category of Work Subcontractor and Address 1. Electrical Gulf States Electric,Inc.-4585 Progress Avenue,Naples,FL 34104 2. Mechanical 3. Plumbing 4. Site Work 5. Identify other subcontractors that represent more than 10% of price or that affect the critical path of the schedule Company: R2T,Inc. C" —_ Signature: � ► Date: 6/5/2020 Construction Solicitation Doc rev 02-21-20 ICAO FORM 5-STATEMENT OF EXPERIENCE OF BIDDER The Bidder is required to state below what work of similar magnitude completed within the last five (5) years is a judge of its experience, skill and business standing and of its ability to conduct the work as completely and as rapidly as required under the terms of the Agreement. 1• NaOCL, Biosolids,and Filter System Improvements at Tropical Farms&North Treament Facilities Martin County Utilities (project name) (project owner) Stuart, FL 3473 SE Willoughby Boulevard, Stuart, FL 34996 (project location) (Owner's address) See Attached Darrell Schuler Project Manager (project description) (Owner's contact person) (title) 3/2018 - 2/2020 $$4,924,000 772.223.7957 dschuler@martin.fl.us (project start/completion dates) (contract value) (phone) (email) PGA WWTP Blower Building, Nitrified 2 Recycle Pump Station, and Misc Electrical Improvements Seacoast Utility Authority (project name) (project owner) Palm Beach Gardens, FL 4200 Hood Road, Palm Beach Gardens, FL 33410 (project location) (Owner's address) See Attached Brent Weidenhamer WW Department Manager (project description) (Owner's contact person) (title) 10/2018 - 5/2020 $5,245,490 561.627.2900 bweidenhamer@sua.com (project start/completion dates) (contract value) (phone) (email) Noonday Creek WRF Chemical Feed 3. Improvements Cobb County Water System (project name) (project owner) Woodstock, GA 660 S Cobb Drive, Marietta, GA 30060 (project location) (Owner's address) See Attached Jake Murray Project Engineer (project description) (Owner's contact person) (title) 10/2018 - 10/2019 $2,237,955 770.419.6345 jake.murray@cobbcounty.org (project start/completion dates) (contract value) (phone) (email) Construction Solicitation Doc rev 02-21-20 C1O FORM 5-STATEMENT OF EXPERIENCE OF BIDDER 4. DEP Pine Avenue FM Extension and Pump Station Rehabilitation City of Green Cove Springs (project name) (project owner) Green Cove Springs, FL 321 Walnut Street, Green Cove Springs, FL 32043 (project location) (Owner's address) See Attached Scott Schultz Water Utilities Director (project description) (Owner's contact person) (title) 3/2019 - 3/2020 $2,013,731 904.297.7060 sschultz@greencovesprings.com (project completion date) (contract value) (phone) (email) 5. Northwest Cobb WRF Clarifier Splitter System Cobb CountyWater Box Gate Replacement (project name) (project owner) Kennesaw 321 Walnut Street, Green Cove Springs, FL 32043 (project location) (Owner's address) See Attached Mike Roper Superintendent (project description) (Owner's contact person) (title) 9/2019 - 2/2020 $143,422 770.917.5194 michael.roper@cobbcounty.org (project completion date) (contract value) (phone) (email) 6. (project name) (project owner) (project location) (Owner's address) (project description) (Owner's contact person) (title) (project completion date) (contract value) (phone) (email) Company: R2T, Inc. Signature: > Date: June 5, 2020 Construction Solicitation Doc rev 02-21-20 CAO Form 5 — Statement of Experience of Bidder 1. NaOCL, 13iosolids, and Filter S stem Im rovements at Tro ical Farms & North Treatment Facilities Project Location: Stuart, FL Project Owner: Martin County Utilities Owner Contact: Darrell Schuler Title: Project Manager Owner Address: 3473 SE Willoughby Boulevard Telephone: 772.223.7957 Stuart,FL 34996 Email: dschulerrudmartin.fl.us Project Dates: 3/2018—2/2020 Contract Value: $4,924,000 Project Description: This project is for the expansion and rehabilitation of an .°"R q existingWTP and WWTP and the Tropical Farms and North Facilities. The project involved the replacement of the exiting chemical feed and storage systems and structures. Effluent filters to replace undersized basins i 1s were installed. The WAS feed systems to the dewatering facilities were constructed to improve efficiency of the systems. Specifically, R2T constructed the following: = � • Containment Structures: Constructed new WTP and WWTP containment areas at Tropical Farms Facilities. One basin provided containment for a single 15,000-gallon storage tanks. The second provided containment for a single 15,000-gallon FRP tank. • FRP Tanks: Provided and installed 6 new 15,000-gal FRP NaOCI tanks and 1 new 1600-gallon day tank for the Tropical and North Treatment Facilities. • NaOCL Chemical Feed Systems: Installed two new chemical feed skids for the WTP and WWTP at the Tropical Farms Facility.These new skids replaced the existing feed and transfer systems. • Chemical Feed Piping: Extensive replacement and rerouting of the chemical feed systems with fusion welded HDPE NaOCL piping and valves. • Effluent Filters: Constructed new effluent filter process area.Installed influent, effluent, bypass, overflow, and backwash piping system to provide and convey effluent water to and from the filters. Provided and installed three new disc filters capable of 10 MGD per filter. • WAS Pumps and Macerator: Provided and installed I WAS pumps and WAS macerators at the Tropical Farms and North Treatment Facilities. Installed all new piping systems to receive and convey WAS flow for sludge disposal. • Electrical and I&C: Provided complete electrical and I&C systems for the new process equipment systems. Total electrical and I&C value was approximately h $700k on this project due to the extensive work. /� � Project No. 20-009R Lift Station Rehabilitation Continuing Construction Contract 2020 Page 1 of 5 S Form 5 — Statement of Experience of Bidder 2. PGA Wastewater Treatment Plant Blower Building,Nitrified Recycle Pump Station (NRCY)and Miscellaneous Electrical Im rovements Project Location: Palm Beach Gardens, FL Project Owner: Seacoast Utility Authority Owner Contact: Brent Weidenhamer Title: WW Department Manager Owner Address: 4200 Hood Road Telephone: 561.627.2900 ext 1494 Palm Beach Gardens, FL Email: bweidenhamer(a sua.com 33410 Project Dates: 10/2018—5/2020 Contract Value: $5,245,490 Project Description: R2T provided for the construction of a new blower building,NRCY pump station and multiple electrical upgrades to the existing 12 MGD PGA WWTP. Specifically, R2T constructed the following: • Blower Building: Constructed new 2500 sq. ft, 26' tall concrete, CMU and prestressed double Tee building to house the 6 new aeration blowers and associated piping. Multiple piping e4t, cx3 e systems and existing structures were either demolished or relocated for the construction of the new building. 41{how • Blowers: Provided and installed 6 new blowers. 4 are multistage (111 centrifugal blowers and 2 are turbo blowers capable of providing aeration needs to a 12 MGD WWTP facility.Part of the a ; installation requires the decommissioning and demolition of the � a existing blower systems.A multiphase approach is required to complete the installation. • Yard Piping: Constructed new above ground blower discharge piping to come from the new blower building and tie into the existing piping for various process basins.New concrete and structural steel elements are required to install the new piping. • Nitrified Recycle Pump Station: Demolished and installed new NRCY pump station with new piping, concrete structure, pumps, and associated equipment. Included the addition of 3 new dry pit vertical chopper pumps. • Electrical Upgrades: Provided for replacement,reconfiguring and new electrical systems to power the existing facility,new equipment and relocated equipment. Multi phased approach required to keep the existing facility in operation while new systems were installed. Total electrical package is approximately $1.4M. • Pond Cleaning: R2T was issued a change order to remove existing sludge from the facilities settling ponds. Approximately 600 yds of sludge were dredged from the pond bottoms. • Basin Cleaning: R2T was issued a change order to remove the sludge and grit from the existing digester basins. These basins were dewatered, and the aluminum covers were removed for access. Approximately 6' of material was removed from the bottom of the basin and disposed of. Project No. 20-009R Lift Station Rehabilitation Continuing Construction Contract 2020 Page 2 of 5 ICAO Form 5 — Statement of Experience of Bidder 3. Noonda Water Reclamation Facili Chemical Feed Im rovements Project Location: Woodstock, GA Project Owner: Cobb County Water System Owner Contact: Jake Murray, PE Title: Project Engineer Owner Address: 660 S Cobb Drive Telephone: 770.419.6345 Marietta, GA 30060 Email: Jake.murray@cobbcounty.org ; Project Dates: 10/2018— 10/2019 Contract Value: $2,237,955 Project Description: The Project involves demolishing existing chemical feed facilities and installing new chemical feed facilities and consists of the following major components: • Install temporary chemical feed facilities for the tqlf op, existing ferrous chloride, sodium hypochlorite, and • sodium bisulfite chemical feed systems. I • Demolish existing ferrous chloride feed system �. including bulk storage tanks, chemical feed pumps, control panels, chemical piping,electrical conduit € and wiring, and appurtenances. - A - • Demolish existing sodium hypochlorite feed system including bulk storage tanks,chemical feed pumps, control panels, chemical piping,electrical conduit and wiring, and appurtenances. . -z- u • Demolish existing sodium bisulfite feed pumps, control panels, associated piping, and appurtenances. • Demolish other chemical pumps and appurtenances as specified. • Remove and replace existing chemical piping between bulk storage tanks and chemical feed building. • Remove and replace existing ferrous chloride, sodium hypochlorite,and sodium bisulfite distribution pipe between chemical feed building and discharge locations. • Install new ferrous chloride feed equipment including bulk storage tanks,peristaltic hose pumps,pump control panels, chemical piping,electrical conduit and wiring, and appurtenances. • Install new sodium hypochlorite feed equipment including bulk storage tanks,peristaltic hose pumps, pump control panels, chemical piping,electrical conduit and wiring, and appurtenances. • Install new sodium hydroxide peristaltic hose pump, pump control panel, chemical piping, electrical conduit and wiring, and appurtenances. • Install new sodium bisulfite peristaltic hose pumps,pump control panels,chemical piping, electrical conduit and wiring, and appurtenances. • Remove existing safety eyewash/shower stations and install new safety eyewash/shower stations. • Remove and dispose of two abandoned chemical storage tanks, in addition to tanks above. • Erosion and sediment control, site cleanup, and all other activities required to complete the project. Project No. 20-009R Lift Station Rehabilitation Continuing Construction Contract 2020 Page 3 of 5 Form 5 — Statement of Experience of Bidder 4. DEP SRF Pine Ave. Force Main Extension & I'S Nos. 2 &4 Rehabilitation,Phase 1 Project Location: Green Cove Springs, FL Owner Contact: City of Green Cove Springs Project Owner: Scott Schultz Title: Water Utilities Director Owner Address: 321 Walnut Street Telephone: 904.297.7060 Green Cove Springs, FL Email: Sschultz(ii greencovesprings.com 32043 Project Dates: 3/2019—3/2020 Contract Value: $2,013,731 Project Description: Rehabilitation of two existing submersible pump stations rd;h . : , (Pump Station Nos. 2&4).Pump Station No. 2 is a triplex rehab, and Pump Station No. 4 is an existing duplex station _ that will be converted to a triplex station with complete removal and replacement of all mechanical and electrical at each station. l Specifically, R2T completed the following: p • Installation of a 24 hrs per day bypass system at each site. • Demolition and removal of all existing pumping and piping i in equipment • Installation of new liner in two 30 ft deep wet wells. • Installation of three submersible pumps and associated piping and valves at each station. • Installation of new generator at each pump station `` � � • Installation of a new jockey/portable pump at each � � station. • Installation of odor control system at each stations °a _ • Site repair work including fencing, paving concrete �� � driveway. • Complete replacement of electric system and I&C components. may. Project No. 20-009R Page 4 of 5 Lift Station Rehabilitation Continuing Construction Contract 2020 'LAp Form 5 — Statement of Experience of Bidder 5. Northwest Cobb WRF Clarifier S litter Box Cate Re lacement Project Location: Kennesaw, GA Project Owner: Cobb County Water System Owner Contact: Mike Roper Title: Superintendent Owner Address: 122 Waddell Street NE Telephone: 770.917.5194 Marietta, GA 30060 Email: michael.roper'cb,cobbcounorg Project Dates: 9/2019—2/2020 Contract Value: $143,422 Project Description: This project included the installation of fabricated aluminum weir gates, provided with motorized actuators, and the removal of the existing weir gates(SG-1021, SG-1022 and SG-1023), gate motorized actuators, and the existing gate disconnection switches. Project No. 20-009R Lift Station Rehabilitation Continuing Construction Contract 2020 Page 5 of 5 Cq�� FORM 6-TRENCH SAFETY ACT Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act(90-96,Laws of Florida)effective October 1, 1990.The Bidder further identifies the cost to be summarized below: Trench Safety Units of Unit Unit Extended Cost Measure Measure (Quantity) Cost (Description) (LF,SY) 1 Trench Box LF 100 $20.00 $2000 2. 3. 4. 5. TOTAL $2000 Failure to complete the above may result in the Bid being declared non-responsive. Company: R2T,Inc. Signature: "�;-� y Date: 6/5/2020 Construction Solicitation Doc rev 02-21-20 Collier County Solicitation 20-7763 FORM 7-BID BOND KNOW ALL MEN BY THESE PRESENTS, that we R2T, Inc. (herein after called the Principal) and GreatAmeriran Insurance Company , (herein called the Surety), a corporation chartered and existing under the laws of the State of 0i1iQ with its principal offices in the city of Cinrinnatti and authorized to do business in the State of Florida are held and firmly bound unto the Collier County Board of Commissioners (hereinafter called the Owner),in the full and just sum of Five Percent of Amount Bid dollars($ 5% )good and lawful money of the United States of America,to be paid upon demand of the Owner,to which payment well and truly to be made,the Principal and the Surety bind themselves,their heirs,and executors,administrators,and assigns,jointly and severally and firmly by these presents. Whereas,the Principal is about to submit,or has submitted to the Owner, a Bid for furnishing all labor, materials, equipment and incidentals necessary to furnish,install,and fully complete the Work on the Project known as Bid No. 20-7763 NCWRF Effluent Filters No.2&3 Equipment Replacement. NOW,THEREFORE, if the Owner shall accept the Bid of the PRINCIPAL and the PRINCIPAL shall enter into the required Agreement with the Owner and within ten days after the date of a written Notice of Award in accordance with the terms of such Bid,and give such bond or bonds in an amount of 100%the total Contract Amount as specified in the Bidding Documents or Contract Documents with good and sufficient surety for the faithful performance of the Agreement and for the prompt payment of labor,materials and supplies furnished in the prosecution thereof or,in the event of the failure of the PRINCIPAL to enter into such Agreement or to give such bond or bonds,and deliver to Owner the required certificates of insurance,if the PRINCIPAL shall pay to the OBLIGEE the fixed sum of$5%of Amount Bid noted above as liquidated damages,and not as a penalty,as provided in the Bidding Documents,then this obligation shall be null and void,otherwise to remain in full force and effect. IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly signed and sealed this Leib_ day of June ,2020. R2T, Inc. Principal,•% • GOptPORgr. BY ,C (Seal) r'eat American In ranee Company Surety 2005 /Miffi4� (Seal) ��.,� fi . .•• •``���� J/ rik McMichael,Attorney-in-Fact �� ORICS w% Countersigned No Longer Required ���tri�ttt�� Appointed Producing Agent for Great American Insurance Company 5/15/2020 2:24 PM p.14 S • GREAT AMERICAN INSURANCE COMPANY® Administrative Office: 301 E 4TH STREET • CINCINNATI,OHIO 45202 • 513-369-5000 • FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than FOUR No.0 21343 POWER OF ATTORNEY KNOW ALL MEN BYTHESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY,a corporation organized and existing under and by virtue of the laws of the State of Ohio,does hereby nominate,constitute and appoint the person or persons named below,each individually if more than one is named,its true and lawful attomey-in-fact,for it and in its name,place and stead to execute on behalf of the said Company,as surety,any and all bonds, undertakings and contracts of suretyship,or other written obligations in the nature thereof;provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. Name Address Limit of Power SUZANNE YEATMAN ALL OF ALL JENNIFER S.FREEMAN NEWMAN,GEORGIA $100,000,000 J.ERIK MCMICHAEL MICHELLE DELIGNE This Power of Attorney revokes all previous powers issued on behalf of the attorneys)-in-fact named above. IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this 23RD day of JULY 2019 Attest GREAT AMERICAN INSU NCE COMPAN 7!kt4 3 e i/ ma& Assistant Seeman). Divisional Senior Vice President STATE OF OHIO,COUNTY OF HAMILTON-ss; MARK VICARIO 077-377-240G) On this 23RD day of JULY , 2019 ,before me personally appeared MARK V ICARIO,to me known, being duly sworn,deposes and says that he resides in Cincinnati,Ohio,that he is a Divisional Senior Vice President of the Bond Division of Great American insurance Company,the Company described in and which executed the above instrument;that he knows the seal of the said Company;that the seal affixed to the said instrument is such corporate seal;that it was so affixed by authority of his office under the By-Laws of said Company,and that he signed his name thereto by like authority. oly Susan A Krohorst i ---: Notary Pubic,ebbot 4 CIC A' Qt a y Lf•' ,'' My Coorobolort Emirs mono This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company by unanimous written consent dated June 9,2008. RESOLVED: That the Divisional President,the several Divisional Senior ice Presidents,Divisional Vice Presidents and Divisoncd Assistant Vice Presidents,or any one of them,be and hereby is aut ori_ed,,from time to time,to appoint one or more Attorneys-in-Fact to execute on behalf of the Company, as surety,ant'and crll bonds,undertakings and contracts ofsuretyship,or other written obligations in the nature thereof,to prescribe their respective duties and the respective limits of their authority;and to revoke any such appointment at any time. RESOLVED FURTHER: That the Company seal and the signature of any of the aforesaid officers and any Secretary or Assistant Secretory of the Company oum be affixed by facsimile to any power of attorney or certificate of either given.for the execution of any bond,undertaking,contract of suretyship, or other written obligation in the nature thereof,such signature and sectl when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company,to be valid and binding upon the Company with the sane force and effect as though manually affixed. CERTIFICATION I,STEPHEN C.BERAHA,Assistant Secretary of Great American insurance Company,do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of June 9,2008 have not been revoked and are now in full force and effect. Signed and sealed this 16th day of June , 2020 .c,{k Assistant Secretary 51029AG(07/1 aJ CA O FORM 8-INSURANCE AND BONDING REQUIREMENTS The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in FORM 8 of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project,if required,to the full insurable value of the scope of work. The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design Consultant,Subcontractors,agents and employees of each and all of them,all damages covered by property insurance provided herein,except such rights as they may have to the proceeds of such insurance. The Vendor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify"For any and all work performed on behalf of Collier County",or,the specific solicitation number and title. The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interest's provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County,OR Collier County Government,OR Collier County.The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in FORM 8 with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Vendor has any self- insured retentions or deductibles under any of the below listed minimum required coverage,Vendor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be Vendor's sole responsibility. CoverageL shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation,whichever is longer. The Vendor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non-renewal on the part of the insurance carrier or the Vendor. The Vendor shall also notify the County, in a like manner,within twenty-four(24)hours after receipt,of any notices of expiration,cancellation,non- renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder,Vendor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverageW required herein,the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coveragel and charge the Vendor for such coverageL purchased. If Vendor fails to reimburse the County for such costs within thirty (30)days after demand, the County has the right to offset these costs from any amount due Vendor under this Agreement or any other agreement between the County and Vendor.The County shall be under no obligation to purchase such insurance,nor shall it be responsible for the coverageL purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverageW shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s)shall be considered justification for the County to terminate any and all contracts. CA() Collier County Florida Insurance and Bonding Requirements Insurance/Bond Type Required Limits 1. ❑Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers'Compensation coverage or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof of exemption.An application for exemption can be obtained online at https://apps.fldfs.com/boeexemptl 2. ®Employer's Liability $_1,000,000 single limit per occurrence 3. ® Commercial General Bodily Injury and Property Damage Liability(Occurrence Form)patterned after the $_1,000,000 single limit per occurrence, $2,000,000 aggregate for current ISO form Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. ® Indemnification To the maximum extent permitted by Florida law, the Contractor/Vendor shall defend,indemnify and hold harmless Collier County,its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys'fees and paralegals'fees,to the extent caused by the negligence, recklessness,or intentionally wrongful conduct of the Contractor/Vendor or anyone employed or utilized by the ContractorNendor in the performance of this Agreement. 5. ®Automobile Liability $1,000,000 Each Occurrence; Bodily Injury & Property Damage, Owned/Non-owned/Hired;Automobile Included 6. ❑ Other insurance as ❑ Watercraft $ Per Occurrence noted: ❑ United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑ Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑ Aircraft Liability coverage shall be carried in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. $ Per Occurrence ❑ Pollution $ Per Occurrence ❑ Professional Liability $ Per claim &in the aggregate ❑ Project Professional Liability $ Per Occurrence ❑ Valuable Papers Insurance $ Per Occurrence ❑ Cyber Liability $ Per Occurrence 0 Technology Errors&Omissions $ Per Occurrence CA O 7. ®Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit,a cash bond posted with the County Clerk,or proposal bond in a sum equal to 5%of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving award, and written for 100%of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide,published by A.M. Best Company,Inc.of 75 Fulton Street,New York,New York 10038. 9. ® Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. 10. ® Collier County must be named as"ADDITIONAL INSURED"on the Insurance Certificate for Commercial General Liability where required.This insurance shall be primary and non-contributory with respect to any other insurance maintained by,or available for the benefit of,the Additional Insured and the Vendor's policy shall be endorsed accordingly. 11. ® The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County,OR Collier County Government,OR Collier County. The Certificates of Insurance must state the Contract Number,or Project Number,or specific Project description,or must read: For any and all work performed on behalf of Collier County. 12. ® On all certificates, the Certificate Holder must read: Collier County Board of Commissioners, 3295 Tamiami Trail East,Naples, FL 34112 13. ® Thirty(30)Days Cancellation Notice required. 14. Collier County shall procure and maintain Builders Risk Insurance on all construction projects where it is deemed necessary. Such coverage shall be endorsed to cover the interests of Collier County as well as the Contractor. Premiums shall be billed to the project and the Contractor shall not include Builders Risk premiums in its project proposal or project billings. All questions regarding Builder's Risk Insurance will be addressed by the Collier County Risk Management Division. 4/24/20-CC Vendor's Insurance Acceptance By submission of the bid Vendor accepts and understands the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. The insurance submitted must provide coverage for a minimum of six(6)months from the date of award. CA 0 CoCot icr County Administrative Services Department F!,x_urement Services Division FORM 9-CONFLICT OF INTEREST AFFIDAVIT The Vendor certifies that,to the best of its knowledge and belief,the past and current work on any Collier County project affiliated with this solicitation does not pose an organizational conflict as described by one of the three categories below: Biased ground rules—The firm has not set the"ground rules"for affiliated past or current Collier County project identified above (e.g., writing a procurement's statement of work, specifications, or performing systems engineering and technical direction for the procurement)which appears to skew the competition in favor of my firm. Impaired objectivity—The firm has not performed work on an affiliated past or current Collier County project identified above to evaluate proposals'past performance of itself or a competitor,which calls into question the contractor's ability to render impartial advice to the government. Unequal access to information —The firm has not had access to nonpublic information as part of its performance of a Collier County project identified above which may have provided the contractor (or an affiliate)with an unfair competitive advantage in current or future solicitations and contracts. In addition to this signed affidavit,the contractor!vendor must provide the following: 1. All documents produced as a result of the work completed in the past or currently being worked on for the above- mentioned project;and, 2. Indicate if the information produced was obtained as a matter of public record(in the"sunshine")or through non- public(not in the"sunshine")conversation(s),meeting(s),document(s)and/or other means. Failure to disclose all material or having an organizational conflict in one or more of the three categories above be identified,may result in the disqualification for future solicitations affiliated with the above referenced project(s). By the signature below,the firm(employees,officers and/or agents)certifies,and hereby discloses,that,to the best of their knowledge and belief, all relevant facts concerning past, present, or currently planned interest or activity (financial, contractual, organizational, or otherwise) which relates to the project identified above has been fully disclosed and does not pose an organizational conflict. R2T,Inc. m v •me ignature Geor e Pri tName and Title State of Georgia County of Fulton The foregoing instrument was acknowledged before me by means of®physical presence or❑ online notarization, this 15th day of June (month),2020 (year),by George Ajv J (name of person acknowledging). • v/,.-- (Signatlrre 'Notary Public-State of Florida)Georgia Nadya Marinin (Print,Type,or Stamp Commit, �iNin of Notary Public) Personal( Known OR Produced Identification �%•v. N �• '`j �GpMAii� .9 Type of Identification Produced O 0) Y NO � 40. <tc ro: ',i��� tGS �` CA 0 Co:tier County Administrative Services Department Practarenient Services Division FORM 10-VENDOR DECLARATION STATEMENT BOARD OF COUNTY COMMISSIONERS Collier County Government Complex Naples,Florida 34112 Dear Commissioners: The undersigned, as Vendor declares that this response is made without connection or arrangement with any other person and this proposal is in every respect fair and made in good faith,without collusion or fraud. The Vendor hereby declares the instructions,purchase order terms and conditions,requirements, and specifications/scope of work of this solicitation have been fully examined and accepted. The Vendor agrees,if this solicitation submittal is accepted, to execute a Collier County document for the purpose of establishing a formal contractual relationship between the firm and Collier County, for the performance of all requirements to which the solicitation pertains. The Vendor states that the submitted is based upon the documents listed by the above referenced Solicitation. Further,the vendor agrees that if awarded a contract for these goods and/or services,the vendor will not be eligible to compete,submit a proposal,be awarded,or perform as a sub- vendor for any future associated with work that is a result of this awarded contract. IN WITNESS WHEREOF,WE have hereunto subscribed our names on this 5 day of June ,2020 in the County of Fulton ,in the State of Georgia Firm's Legal R2T,Inc. Name: Address: 500 Village Square Crossing,Suite 202 City,State,Zip Palm Beach Gardens,FL 33410 Code: Florida F05000003590 Certificate of Authority Document Number Federal Tax 20-2835149 Identification Number 4R9Z8 *CCR#or CAGE Code *Only if Grant Funded Telephone: 561-775-0009 Email: george.ajy@r2tinc.com Signature by: George Ajy,PE,UM,UC (Typed and written) Title: Vicc President S Additional Contact Information Send payments to: R2T,Inc. (required if different Company name used as payee from above) Contact name: Nadya Marinina Title: Office Manager Address: 580 W Crossville Road,Suite 101 City,State,ZIP Roswell,GA 30075 Telephone: 770-569-7038 Email: nadya.marinina@r2tinc.com Office servicing Collier R2T,Inc. County to place orders (required if different from above) Contact name: George Aiy,PE,UM,UC Title: Vice President Address: 500 Village Sauare Crossing.Suite 202 City,State,ZIP Palm Beach Gardens,FL 33410 Telephone: 561-775-0009 Email: george.ajy@r2tinc.com Secondary Contact for JT Kohrman this Solicitation: Email: jt.kohrman@r2tinc.com Phone: 561-775-0009 CD CoColter County Admniss rativo Services Department Procutenvnt SEIVICe6 Division FORM 11-IMMIGRATION AFFIDAVIT CERTIFICATION This Affidavit is required and should be signed,notarized by an authorized principal of the firm and submitted with formal solicitation submittals. Further, Vendors are required to be enrolled in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Vendor's bid. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company which will be produced at the time of the submission of the Vendor's bid or within five(5)day of the County's Notice of Recommend Award. FAILURE TO EXECUTE THIS AFFIDAVIT CERTIFICATION AND SUBMIT WITH VENDOR'S PROPOSAL/BID MAY DEEM THE VENDOR NON-RESPONSIVE. Collier County will not intentionally award County contracts to any Vendor who knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 U.S.C. Section 1324 a(e) Section 274A(e)of the Immigration and Nationality Act("INA"). Collier County may consider the employment by any Vendor of unauthorized aliens a violation of Section 274A(e) of the INA. Such Violation by the recipient of the Employment Provisions contained in Section 274A(e)of the INA shall be grounds for unilateral termination of the contract by Collier County. Vendor attests that they are fully compliant with all applicable immigration laws(specifically to the 1986 Immigration Act and subsequent Amendment(s))and agrees to comply with the provisions of the Memorandum of Understanding with E-Verify and to provide proof of enrollment in The Employment Eligibility Verification System (E-Verify), operated by the Department of Homeland Security in partnership with the Social Security Administration at the time of submission of the Vendor's bid. R2T,Inc. Compz Name ' 7 _ . ure _me Ajy„PE,UG ice Ident_ Print Na "e and Title State of Georgia_____,._ County of Fulton The foregoing instrument was acknowledged before me by means of 0 physical presence or 0 online notarization, this 15th day of June (month), 2020 (year),by George Ajy (name of person acknowledging). r Z-' (Sio at c''of Notary Public-State of Florida) Georgia NadyaMarnira i (Print,Type,or'Stamp Commissioned Name of Notary Public) Personall Known OR Produced Identification ``toIltttigh A Type of Identification Produced =�`�+Pe�.••''tstir• ' ! '1OT4 9M G •.. 2 r 1 '1/Bt-1C+ .7:. "e t^ e� ei iaUNr(, + illltlaMlllll�l . FORM 12-BIDDERS CHECKLIST IMPORTANT: Please read carefully,sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: V 1. The Bid has been signed. V 2. The Bid prices offered have been reviewed. V 3. The price extensions and totals have been checked. V 4. Bid Schedule has been completed and attached. V 5. Any required drawings,descriptive literature,etc.have been included. V 6. Any delivery information required is included. V 7. The following on-line standard documents have been reviewed and accepted in BidSync: ,/ a. Construction bid instructions form ,/ b. Construction services agreement ✓ c. Purchase order terms and conditions V 8. All of the following bid forms have been completed and signed: V a. Bid Form(Form 1) V b. Contractors Key Personnel(Form 2) V c. Material Manufacturers(Form 3) ,/d. List of Major Subcontractors(Form 4) V e. Statement of Experience(Form 5) V f. Trench Safety Act(Form 6) ✓g. Bid Bond Form(Form 7) V h. Insurance and Bonding Requirements(Form 8) V i. Conflict of Interest Affidavit(Form 9) ,/j. Vendor Declaration Statement(Form 10) ✓k. Immigration Law Affidavit Certification(Form 11)MUST be signed and attached with your submittal or you MAY be DEEMED NON-RESPONSIVE V 1. Signed Grants Provisions and Assurances Package in its entirety,if applicable,are executed and should be included with your submittal. All forms must be executed,or you MAY be DEEMED NON-RESPONSIVE V 9. Copies of required information have been attached a. Business tax Receipt(Collier County Businesses Only) b. Company's E-Verify profile page or memorandum of understanding c. Certificate of Authority to Conduct Business in State of Florida(sunbiz.org) d. Any required professional licenses—valid and current(myfloridalicense.com) (ie:General Contractors license, Underground Utility and Excavation,Builders, Trade Contractors,etc.,as applicable,requested and/or required.) ✓10. If required,the amount of Bid bond has been checked,and the Bid bond or cashier's check has been submitted. V 1 1. Any addenda have been signed and acknowledgement form attached and included,or you MAY be DEEMED NON-RESPONSIVE. V 12. The Bid will be uploaded in time to be received no later than the specified opening date and time,otherwise the Bid cannot be considered. NIB ,,,,*, ,,,./N,,,,s.,, .. .... e y .'i Ililll Company ID Number: 107167 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DHS) and the R2T, Inc. (Employer). The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E-Verify. E-Verify is a program that electronically confirms an employee's eligibility to work in the United States after completion of Form 1-9, Employment Eligibility Verification (Form 1-9). This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer, the Social Security Administration (SSA), and DHS. Authority for the E-Verify program is found in Title IV, Subtitle A, of the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Pub. L. 104-208, 110 Stat. 3009, as amended (8 U.S.C. § 1324a note). The Federal Acquisition Regulation (FAR) Subpart 22.18,"Employment Eligibility Verification"and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal contractor) to use E-Verify to verify the employment eligibility of certain employees working on Federal contracts. ARTICLE II RESPONSIBILITIES A. RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system: a. Notice of E-Verify Participation b. Notice of Right to Work 2. The Employer agrees to provide to the SSA and DHS the names, titles, addresses, and telephone numbers of the Employer representatives to be contacted about E-Verify. The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes. 3. The Employer agrees to grant E-Verify access only to current employees who need E-Verify access. Employers must promptly terminate an employee's E-Verify access if the employer is separated from the company or no longer needs access to E-Verify. Page 1 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 �t t" j/r��,;1 ' E-Verify 1 �a IyE111 Company ID Number: 107167 4. The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual. 5. The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases. a. The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E-Verify in order to continue using E-Verify. Failure to complete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify. 6. The Employer agrees to comply with current Form 1-9 procedures, with two exceptions: a. If an employee presents a "List B" identity document, the Employer agrees to only accept"List B" documents that contain a photo. (List B documents identified in 8 C.F.R. § 274a.2(b)(1)(B)) can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218. b. If an employee presents a DHS Form 1-551 (Permanent Resident Card), Form 1-766 (Employment Authorization Document), or U.S. Passport or Passport Card to complete Form 1-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employee's Form 1-9. The Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest. DHS may in the future designate other documents that activate the photo screening tool. Note: Subject only to the exceptions noted previously in this paragraph,employees still retain the right to present any List A, or List B and List C, document(s) to complete the Form 1-9. 7. The Employer agrees to record the case verification number on the employee's Form 1-9 or to print the screen containing the case verification number and attach it to the employee's Form 1-9. 8. The Employer agrees that, although it participates in E-Verify, the Employer has a responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 274B of the INA with respect to Form 1-9 procedures. a. The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti-discrimination provision of the INA: (1) List B identity documents must have photos,as described in paragraph 6 above; (2)When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(a)(1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and $1,100 for each failure to notify DHS of continued employment following a final nonconfirmation; (4) If the Employer continues to employ an employee after receiving a final nonconfirmation, then the Employer is subject to a rebuttable presumption that it has knowingly Page 2 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 LJ� � II���ti.. E-Verify foiiili Company ID Number: 107167 employed an unauthorized alien in violation of section 274A(a)(1)(A); and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b. DHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verify. 9. The Employer is strictly prohibited from creating an E-Verify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed. The Employer agrees to create an E-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections 1 and 2 of Form 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual. If E-Verify is temporarily unavailable,the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting, in good faith, to make inquiries during the period of unavailability. 10. The Employer agrees not to use E-Verify for pre-employment screening of job applicants, in support of any unlawful employment practice, or for any other use that this MOU or the E-Verify User Manual does not authorize. 11. The Employer must use E-Verify for all new employees. The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU. Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article 11.13 of this MOU. 12. The Employer agrees to follow appropriate procedures(see Article III below) regarding tentative nonconfirmations. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmation based upon a photo mismatch, the Employer must take additional steps (see Article 111.B. below) to contact DHS with information necessary to resolve the challenge. 13. The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a.1(I))that the employee is not work authorized.The Employer understands that an initial inabifty of the SSA or DHS automated verification system to verify work authorization, a tentative nonconfirmation, a case in continuance (indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized. In any of such cases, the employee must be provided a full and fair opportunity to contest the finding, and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status Page 3 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 E WIN 141iDI Company ID Number: 107167 (including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued. If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment. Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218(customer service) or 1-888-897-7781 (worker hotline). 14. The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 274B of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E-Verify except as provided in part D below, or discharging or refusing to hire employees because they appear or sound "foreign" or have received tentative nonconfirmations. The Employer further understands that any violation of the immigration-related unfair employment practices provisions in section 274B of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject the Employer to back pay awards, compensatory and punitive damages. Violations of either section 274E of the INA or Title VII may also lead to the termination of its participation in E-Verify. If the Employer has any questions relating to the anti-discrimination provision, it should contact OSC at 1-800-255-8155 or 1-800-237-2515(TDD). 15. The Employer agrees that it will use the information it receives from E-Verify only to confirm the employment eligibility of employees as authorized by this MOU. The Employer agrees that it will safeguard this information, and means of access to it(such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU, except for such dissemination as may be authorized in advance by SSA or DHS for legitimate purposes. 16. The Employer agrees to notify DHS immediately in the event of a breach of personal information. Breaches are defined as loss of control or unauthorized access to E-Verify personal data. All suspected or confirmed breaches should be reported by calling 1-888-464-4218 or via email at E-Verify a(�dhs.gov. Please use "Privacy Incident—Password" in the subject line of your email when sending a breach report to E-Verify. 17. The Employer acknowledges that the information it receives from SSA is governed by the Privacy Act(5 U.S.C. § 552a(i)(1) and (3)) and the Social Security Act(42 U.S.C. 1306(a)). Any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties. 18. The Employer agrees to cooperate with DHS and SSA in their compliance monitoring and evaluation of E-Verify, which includes permitting DHS, SSA, their contractors and other agents, upon Page 4 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 , . 1 bs� IIll1U EVer 1� r Company ID Number: 107167 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19. The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media. The Employer shall not describe its services as federally-approved, federally-certified, or federally-recognized, or use language with a similar intent on its website or other materials provided to the public. Entering into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effect is false. 20. The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS. 21. The Employer agrees that E-Verify trademarks and logos may be used only under license by DHS/USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services, products, websites, or publications are sponsored by, endorsed by, licensed by, or affiliated with DHS, USCIS, or E-Verify. 22. The Employer understands that if it uses E-Verify procedures for any purpose other than as authorized by this MOU, the Employer may be subject to appropriate legal action and termination of its participation in E-Verify according to this MOU. B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1. If the Employer is a Federal contractor with the FAR E-Verify clause subject to the employment verification terms in Subpart 22.18 of the FAR, it will become familiar with and comply with the most current version of the E-Verify User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors. 2. In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must verify the employment eligibility of any"employee assigned to the contract" (as defined in FAR 22.1801). Once an employee has been verfied through E-Verify by the Employer, the Employer may not create a second case for the employee through E-Verify. a. An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verify employment eligibility of new hires using E-Verify. The Employer must verify those employees who are working in the United States, whether or not they are assigned to the contract. Once the Employer begins verifying new hires, such verification of new hires must be initiated within three business days after the hire date. Once enrolled in E Verify as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later. Page 5 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 E- rify Company ID Number: 107167 b. Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire. If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award,the Employer must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract. Such verification of new hires must be initiated within three business days after the date of hire. An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later. c. Federal contractors that are institutions of higher education (as defined at 20 U.S.C. 1001(a)), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract. Such Federal contractors may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986. Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later. d. Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United States who were hired after November 6, 1986, instead of verifying only those employees assigned to a covered Federal contract. After enrollment, Employers must elect to verify existing staff following DHS procedures and begin E-Verify verification of all existing employees within 180 days after the election. e. The Employer may use a previously completed Form 1-9 as the basis for creating an E-Verify case for an employee assigned to a contract as long as: i. That Form 1-9 is complete (including the SSN) and complies with Article II.A.6, ii. The employee's work authorization has not expired, and iii. The Employer has reviewed the Form 1-9 information either in person or in communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U.S. citizen). f. The Employer shall complete a new Form 1-9 consistent with Article II.A.6 or update the previous Form 1-9 to provide the necessary information if: i. The Employer cannot determine that Form 1-9 complies with Article II.A.6, ii. The employee's basis for work authorization as attested in Section 1 has expired or changed, or iii. The Form 1-9 contains no SSN or is otherwise incomplete. Note: If Section 1 of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies with Page 6 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CAO E-VeriFy ,./3t, Af:,`t:".;'—':V 1111111 Company ID Number: 107167 Article II.C.5, but reflects documentation (such as a U.S. passport or Form 1-551)that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article II.A.5, subject to any additional or superseding instructions that may be provided on this subject in the E-Verify User Manual. g. The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3. The Employer understands that if it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements. C. RESPONSIBILITIES OF SSA 1. SSA agrees to allow DHS to compare data provided by the Employer against SSA's database. SSA sends DHS confirmation that the data sent either matches or does not match the information in SSA's database. 2. SSA agrees to safeguard the information the Employer provides through E-Verify procedures. SSA also agrees to limit access to such information, as is appropriate by law, to individuals responsible for the verification of Social Security numbers or responsible for evaluation of E-Verify or such other persons or entities who may be authorized by SSA as governed by the Privacy Act (5 U.S.C. § 552a), the Social Security Act (42 U.S.C. 1306(a)), and SSA regulations(20 CFR Part 401). 3. SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry. E-Verify provides the information to the Employer. 4. SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence. If the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, if appropriate, within the eight-day period unless SSA determines that more than eight days may be necessary. In such cases, SSA will provide additional instructions to the employee. If the employee does not visit SSA in the time allowed, E-Verify may provide a final nonconfirmation to the employer. Note: If an Employer experiences technical problems, or has a policy question, the employer should contact E-Verify at 1-888-464-4218. D. RESPONSIBILITIES OF DHS 1. DHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct, to the extent authorized by this MOU: a. Automated verification checks on alien employees by electronic means, and Page 7 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CA() E ,-,„ ,„,„,,,,„ ,„,,,,, z. ,,,,,,,, lll„u Company ID Number: 107167 b. Photo verification checks (when available) on employees. 2. DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. DHS agrees to provide the Employer names, titles, addresses, and telephone numbers of DHS representatives to be contacted during the E-Verify process. 3. DHS agrees to provide to the Employer with access to E-Verify training materials as well as an E-Verify User Manual that contain instructions on E-Verify policies, procedures, and requirements for both SSA and DHS, including restrictions on the use of E-Verify. 4. DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manual. Even without changes to E-Verify, DHS reserves the right to require employers to take mandatory refresher tutorials. 5. DHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E-Verify. DHS also agrees to provide to the Employer anti-discrimination notices issued by the Office of Special Counsel for Immigration-Related Unfair Employment Practices (OSC), Civil Rights Division, U.S. Department of Justice. 6. DHS agrees to issue each of the Employer's E-Verify users a unique user identification number and password that permits them to log in to E-Verify. 7. DHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E-Verify, or to such other persons or entities as may be authorized by applicable law. Information will be used only to verify the accuracy of Social Security numbers and employment eligibility, to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements. 8. DHS agrees to provide a means of automated verification that provides(in conjunction with SSA verification procedures) confirmation or tentative nonconfirmation of employees' employment eligibility within three Federal Government work days of the initial inquiry. 9. DHS agrees to provide a means of secondary verification (including updating DHS records) for employees who contest DHS tentative nonconfirmations and photo mismatch tentative nonconfirmations. This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to DHS, unless OHS determines that more than 10 days may be necessary. In such cases, DHS will provide additional verification instructions. ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA 1. If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify Page 8 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 E . hd. / illiili;\.. Company ID Number: 107167 case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed by E-Verify. The Employer must record the case verification number, review the employee information submitted to E-Verify to identify any errors, and find out whether the employee contests the tentative nonconfirmation. The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again if this review indicates a need to do so. 4. The Employer will instruct the employee to visit an SSA office within eight Federal Government work days. SSA will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 5. While waiting for case results, the Employer agrees to check the E-Verify system regularly for case updates. 6. The Employer agrees not to ask the employee to obtain a printout from the Social Security Administration number database (the Numident) or other written verification of the SSN from the SSA. B. REFERRAL TO DHS 1. If the Employer receives a tentative nonconfirmation issued by OHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. The Employer agrees to refer individuals to DHS only when the employee chooses to contest a tentative nonconfirmation. 4. If the employee contests a tentative nonconfirmation issued by DHS, the Employer will instruct the Page 9 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 ICAO oa II3901 Company ID Number: 107167 employee to contact DHS through its toll-free hotline (as found on the referral letter) within eight Federal Government work days. 5. If the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph 1 of this section for tentative nonconfirmations, generally. 6. The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1-551, Form 1-766, U.S. Passport, or passport card to DHS for review by: a. Scanning and uploading the document, or b. Sending a photocopy of the document by express mail (furnished and paid for by the employer). 7. The Employer understands that if it cannot determine whether there is a photo match/mismatch, the Employer must forward the employee's documentation to DHS as described in the preceding paragraph. The Employer agrees to resolve the case as specified by the DHS representative who will determine the photo match or mismatch. 8. DHS will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 9. While waiting for case results, the Employer agrees to check the E-Verify system regularly for case updates. ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1. SSA and DHS will not charge the Employer for verification services performed under this MOU. The Employer is responsible for providing equipment needed to make inquiries. To access E-Verify, an Employer will need a personal computer with Internet access. ARTICLE V MODIFICATION AND TERMINATION A. MODIFICATION 1. This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and DHS operates the E-Verify program unless modified in writing by the mutual consent of all parties. 2. Any and all E-Verify system enhancements by DHS or SSA, including but not limited to E-Verify checking against additional data sources and instituting new verification policies or procedures, will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes. Page 10 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CAO E-Verify � 1111D1, Company ID Number: 107167 B. TERMINATION 1. The Employer may terminate this MOU and its participation in E-Verify at any time upon 30 days prior written notice to the other parties. 2. Notwithstanding Article V, part A of this MOU, OHS may terminate this MOU, and thereby the Employer's participation in E-Verify, with or without notice at any time if deemed necessary because of the requirements of law or policy, or upon a determination by SSA or DHS that there has been a breach of system integrity or security by the Employer, or a failure on the part of the Employer to comply with established E-Verify procedures and/or legal requirements. The Employer understands that if it is a Federal contractor, termination of this MOU by any party for any reason may negatively affect the performance of its contractual responsibilities. Similarly, the Employer understands that if it is in a state where E-Verify is mandatory, termination of this by any party MOU may negatively affect the Employer's business. 3. An Employer that is a Federal contractor may terminate this MOU when the Federal contract that requires its participation in E-Verify is terminated or completed. In such cases, the Federal contractor must provide written notice to DHS. If an Employer that is a Federal contractor fails to provide such notice, then that Employer will remain an E-Verify participant, will remain bound by the terms of this MOU that apply to non-Federal contractor participants, and will be required to use the E-Verify procedures to verify the employment eligibility of all newly hired employees. 4. The Employer agrees that E-Verify is not liable for any losses, financial or otherwise, if the Employer is terminated from E-Verify. ARTICLE VI PARTIES A. Some or all SSA and OHS responsibilities under this MOU may be performed by contractor(s), and SSA and OHS may adjust verification responsibilities between each other as necessary. By separate agreement with DHS, SSA has agreed to perform its responsibilities as described in this MOU. B. Nothing in this MOU is intended, or should be construed, to create any right or benefit, substantive or procedural, enforceable at law by any third party against the United States, its agencies, officers, or employees, or against the Employer, its agents, officers, or employees. C. The Employer may not assign, directly or indirectly, whether by operation of law, change of control or merger, all or any part of its rights or obligations under this MOU without the prior written consent of OHS, which consent shall not be unreasonably withheld or delayed. Any attempt to sublicense, assign, or transfer any of the rights, duties, or obligations herein is void. D. Each party shall be solely responsible for defending any claim or action against it arising out of or related to E-Verify or this MOU, whether civil or criminal, and for any liability wherefrom, including (but not limited to) any dispute between the Employer and any other person or entity regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by the Employer. E. The Employer understands that its participation in E-Verify is not confidential information and may be disclosed as authorized or required by law and DHS or SSA policy, including but not limited to, Page 11 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CAO E-Verify t .%.. -, i0i,.. Company ID Number: 107167 Congressional oversight, E-Verify publicity and media inquiries, determinations of compliance with Federal contractual requirements, and responses to inquiries under the Freedom of Information Act (FOIA). F. The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer and DHS respectively. The Employer understands that any inaccurate statement, representation, data or other information provided to DHS may subject the Employer, its subcontractors, its employees, or its representatives to: (1) prosecution for false statements pursuant to 18 U.S.C. 1001 and/or; (2) immediate termination of its MOU and/or; (3) possible debarment or suspension. G.The foregoing constitutes the full agreement on this subject between DHS and the Employer. To be accepted as an E-Verify participant, you should only sign the Employer's Section of the signature page. If you have any questions,contact E-Verify at 1-888-464-4218. Page 12 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CA U _ e v,, 'Pl;',,-,- �t lihlll,. Company ID Number: 107167 Approved by: Employer R2T, Inc. Name (Please Type or Print) Title Nereida Haines Signature Date Electronically Signed 03/14/2008 Department of Homeland Security—Verification Division Name (Please Type or Print) Title USCIS Verification Division Signature Date Electronically Signed 03/17/2008 Page 13 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CAO s<, MI i,,,. .,4 ,1%4 .._ e How -- Company ID Number: 107167 Information Required for the E-Verify Program Information relating to your Company: R2T, Inc. Company Name 580 W. Crossville Road Suite 101 Roswell, GA 30075 Company Facility Address Company Alternate Address County or Parish FULTON Employer Identification Number 202835149 North American Industry 541 Classification Systems Code Parent Company Number of Employees 10 to 19 Number of Sites Verified for 3 Page 14 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CAO • ,� k�>, � Ii]ilU Company ID Number: 107167 Are you verifying for more than 1 site? If yes, please provide the number of sites verified for in each State: FLORIDA 1 site(s) GEORGIA 1 site(s) PENNSYLVANIA 1 site(s) Page 15 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 �rY S ,,.�Ililll� rify Company ID Number: 107167 Information relating to the Program Administrator(s)for your Company on policy questions or operational problems: Name Nereida Haines Phone Number (770)569-7038 ext. 108 Fax Number (770)594-7477 Email Address nereida.haines@r2tinc.com Page 16 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 • , ...... E rify pkw. ,,,,,)<%<:,..t. Company ID Number: 107167 Page intentionally left blank Page 17 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 CAO Detail by Entity Name Page 1 of 2 v.S Deoanmerrt o Statc / Dr„s;or.of Corpcoatiors / Search Records / Seorc . E ti y_Name / Detail by Entity Name Foreign Profit Corporation R2T, INC. Filing Information Document Number F05000003590 FEI/EIN Number 20-2835149 Date Filed 06/09/2005 State GA Status ACTIVE Principal Address 500 Village Square Crossing Suite 202 Palm Beach Gardens,FL 33410 Changed: 10/22/2018 Mailing Address 580 W. CROSSVILLE ROAD SUITES 101-102 ROSWELL,GA 30075 Changed: 02/07/2008 Registered Agent Name&Address CT Corporation System 1200 South Pine Island Rd Plantation, FL 33324 Name Changed:02/14/2017 Address Changed: 02/14/2017 Officer/Director Detail Name&Address Title CPD AJY,KIMBERLY 1841 Peeler Rd Unit C Atlanta,GA 30338 C:AO http://search.sunbiz.org/Inquiry/Corporation Search/SearchResultDetai 1?inquirytype=Entity... 7/21/2020 Detail by Entity Name Page 2 of 2 Title VPST AJY,GEORGE 580 W CROSSVILLE ROAD SUITE 101 ROSWELL,GA 30075 Annual Reports Report Year Filed Date 2018 03/08/2018 2019 02/15/2019 2020 03/18/2020 Document Images 03/18/2020--ANNUAL REPORT View image in PDF format 02/15/2019--ANNUAL REPORT View image in PDF format 10/22/2018--AMENDED ANNUAL REPORT View image in PDF format 03/08/2018—ANNUAL REPORT View image ill PDF format 02/14/201 r--ANNUAL.REPORT View image in PDF format 02/12/2016—ANNUAL REPORT View image in PDF format 02/20/2015--ANNUAL REPORT View image in PDF format 03/14/2014--ANNUAL REPORT f View image in PDF format 0'1/07/2013—ANNUAL REPORT View image in PDF format 01/04/2012—ANNUAL REPORT View Image in PDF format 01/03/2011--ANNUAL.REPORT View image in PDF format 01/04/2010—ANNUAL REPORT View image in PDF format 01/08/2009--ANNUAL.REPORT View image in PDF fomiat L2/07/2UC$._-.._ANNU/1l,„REF?nF?T View image in PDF format 01/05/200 7--ANNUAL REPORT View image in PDF format 02/05/2006—ANNUAL REPORT View image in PDF format 06/09/2005—Foreign Profit View image in PDF format ..,^.rich Department of State,C'rfaion of Ce,orations CAO http://search.sunbiz.org/Inquiry/Corporation Search/SearchResultDetai l?inquirytype=Entity... 7/21/2020 State of Florida Department of State I certify from the records of this office that R2T, INC. is a Georgia corporation authorized to transact business in the State of Florida, qualified on June 9, 2005. The document number of this corporation is F05000003590. I further certify that said corporation has paid all fees due this office through December 31, 2020, that its most recent annual report/uniform business report was filed on March 18, 2020, and that its status is active. I further certify that said corporation has not filed a Certificate of Withdrawal. Given under my hand and the Great Seal of the State of Florida at Tallahassee, the Capital, this the Twenty-seventh day of May, 2020 ce 6114(111W * {.. fA41ff V. fy i " c 8 Secretary y of State Tracking Number: 6793621642CU To authenticate this certificate,visit the following site,enter this number,and then follow the instructions displayed. https://services.sunbiz.org/Filings/CertlficateOfStatus/CertificateAuthentication L l.l_ ,....(:)° li O a) I !11 Q w w CU U J m 0 z Z Q V N 0 a) E a) o i 0 Z w VI co O v Q N tn EL:— < 0 o N c ceu p u I p (/) Z -J 0` r-i e� u >, v � � W w 0 a mM ^ � U 0 DJ z e• V) C u = L u- 7 � c O. Ce w _jUw u D 1 Q LL Q zHU LU u o Li- Z (~/) IW F- LU> co W c 7:3o pc 1 , O Q W cc > F- 2 Q •c W V) 0 O a Z Z 0 0 +., c F" W Z U = N Z Z = aj O I O 73 4- F- Z Z Z �' V Z I-- u I Li- O v- j V Z O ( ) ° O / V d 4- c 00 F- DV cn I-- a J a.X > o c W ? -J Q Q LU th •- F- �- > Z Z Z w ° CU U I w W - > — I o 2 Q = a s5 I— V I- p` U Q U' a F- u W ~ 4r, 13.' t r L 1 41,, Ili ha , fp 11 • viir Ctl � r� Yi L J I €0 , Sh..... co aunt-L-C) I 1 Z w 1 0 0 2 i•-• ce a)0 ce>- w 1 1 ' ;;, Z u o LU cc n D (r) , 1 u CI LE LL., (.9 ce 0 .4•J LC) UJ w V) GJ 0 i= I— z Z t..9 (-) < 0 g a) Ln 2 0 Z '112 L.7 17) 0 T-1 CNI u - cn 0 ai E co < tf) 0 < Z CO OS T.1 (1) ci) .(=) a) >, i , UJ uj Li- e7 (.1) (!) -J c•1 _, c -c ra +-. , 1 e.% U I 0 WI C Ce cl I— n3 e-1 0 72 C 1 ' co I U ) u G. >. 0; 4.,, WCZ D 0 LT_ c ia) ew. Lj cc 0 w U D >' a) ce Z 00 0 Z < < = . L' 1 I Li- 0 F. 0 . 1.. — D n CL uj rz III u 0 0 ta) LL Z in I= = UN! i ' a 1— < 03 2 '0 0 < D CI LE >- , LLI In ° < CL ' (-9 U Z , o c i— V) Z (-) < c >. < iict 1.1.1 •■•• I i _1 ui I-- Z Z L.6 U t.' 5 -68 -5 ii Ln TA 0 .... 0 ° -J 0 W Z. C ‘4.- 0 (1/ ° < = li, 03 .1 0 z i1-1-1 , — 1 cc .I z 5 L_1 , o (1) D 0 c 1 u.., IJJ Z 0 Ce Z u - 1 > 0 CL L._ 0 2 u = , o u 0 >. i_ cc o v, ._ 0 u < z v, I— Fe- CI i „gitcolaN N\ 1.— 47' ''1"tk',• ‘si i. .A... _ -1 Arm El • L -,4,Viv-ao i , - DBPR-R2T,INC.,Certificate of Authorization https://www.myfloridalicense.com/LicenseDetail.asp?SID=&id=A785F... 1:40:29 PM 2/18/2019 Licensee Details Licensee Information Name: R2T, INC. (Primary Name) Main Address: 580 WEST CROSSVILLE ROAD SUITE 101 ROSWELL Georgia 30075 License Mailing: 580 W CROSSVILLE ROAD SUITE 101 ROSWELL GA 30075 License Location: License Information License Type: Certificate of Authorization Rank: Cert of Auth License Number: 26505 Status: Current Licensure Date: 07/15/2005 Expires: 02/28/2021 Special Qualifications Qualification Effective Alternate Names View Related License Information View License Complaint 2001 Blair Stone Road,Tallahassee Ft.32399 :: Email: Customer Contact Center::Customer Contact Center: 850.487.1395 The State of Florida is an AA/EEO employer.Copyright 2007-2010 State_of Florida.Privacy Statement Under Florida law,email addresses are public records. If you do not want your email address released in response to a public-records request,do not send electronic mail to this entity. Instead,contact the office by phone or by traditional mail. If you have any questions, please contact 850.487.1395. *Pursuant to Section 455.275(1),Florida Statutes,effective October 1,2012, licensees licensed under Chapter 455,F,S. must provide the Department with an email address if they have one.The emails provided may be used for official communication with the licensee. However email addresses are public record.If you do not wish to supply a personal address, please provide the Department with an email address which can be made available to the public. CAU 1 of I 2/18/2019, 1:40 PM EXHIBIT A-3: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Personnel Category William (Bim) Pope Construction Superintendent Michael Steffen Project Manager Jeff Watson, CGC Construction Manager and Start-up 10 Construction Services Agreement:Revised 072118(v6) SURETY Bonding People And Business Since 1868 August 3, 2020 The Board of County Commissioners of Collier County, FL 3295 Tamiami Trail East, Bldg C-2 Naples, FL 34112 RE: R2T, Inc Bond No.: 2161068—NCWRF Effluent Filters No. 2 & 3 Equipment Replacement To Whom It May Concern: This letter is authorizing The Board of County Commissioners of Collier County, FL to date the above referenced Performance and Payment Bonds the same date of the agreement/Contract(after the Agreement/Contract is executed). If you have any questions,please feel free to call. Thank you, Erik McMichael Attorney-in-Fact for Great American Insurance Company 47 Postal Parkway•Newnan,Georgia 30263 P.O. Box 71429•Newnan,Georgia 30271-1429 770.683.1034•Fax 770.683.1035 EXHIBIT B-1: PUBLIC PAYMENT BOND ITB# 20-7763 Bond No. 2161068 Contract No. 20-7763 KNOW ALL MEN BY THESE PRESENTS: That R2T, Inc. , as Principal, and Great American Insurance Company , as Surety, located at 301 East 14th St., Cincinnati, OH 45902 _ (Business Address) r el and firmly bound to The Board of County Commissioners of Collier County FL as Obligee in the wo it ion even Hundred Fifty Two Thousand Six Hundred Twenty Nine and 00/100 Dollars ($ 2,752,629.00 _) for the sum of payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns,jointly and severally. b __',,,1 WHEREAS, Principal has entered into a contract dated as of the day of e 20 ;, with Obligee for NCWRF Effluent Filters No. 2 &3 Fquipmwni Replacorrlent in Naples, FL accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of fect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this 3rd day of August 20 20 , the name of each party being affixed and these presents duly signed by its under-signed representative, pursuant to authority of its governing body. 11 Construction Services Agreement:Revised 072118(v6) • Signed, sealed and delivered ``�rrrtrirrrori�i in the presence of: PRINCIPAL ::GpRPORAtA �i R2T, Inc. '� nlNr3y. ��/ - = SEAL n 44dop--hi ' /J 2005 Witnesses as to Principal NAME: �� r� '• ©r,��'' .‘ i�rnr�li�e ITS: V. ��rrrriiriko STATE OF 68.779,,, COUNTY OF 7c-4,1/61 The foregoing instrument was acknowledged before me by means of NI physical presence or ❑ online notarization, this ` ,/4 day of A u q us , 20 ?n' , by (;,Ac ALT/ , as ' Y fiacsI1 -' — of 'PZ2T "'WC-. , a `or pe7 .z4bo%, t AO/t corporation, on behalf of the corporation. He/she is personally known__ to me OR has produced _ s identification and did (did not) take an oath. /�' / My Commission Expires: 09/9�/�0�i jj" (Signature of Notary Public) ``00 AMa1,��,P NAME NC1CLA yU an ni r0Q • P0•''ssioy.�/,t1, (LegiblyJ Printed) c•• Q•�.(AFFIX OFFICIAL S1,51q, .�G ..s —4 : Notary Public, State of 1QC�/ tc. .�O,• {d►� ... : Commission No.: Cc/- On O.9 1 ATTEST: """i'Cni NTI.ti%Ni SURETY: /10tt Great American Insurance Company (Printed Name) 301 East 14th St. Cincinnati.OH 45202 (Business Address (Authorized Signature) Witnesses to Surety (Printed Name) 12 Construction Services Agreement:Revised 072118(v6) C,st r;, \ i OR • Jen f Freeman As Attorney in Fact (Attach Power of Attorney) J Erik McMichael Witi j sses Robbie L Hayes (Printed Name) 47 Postal Parkway Newnan, GA 30263 (Business Address) (800) 226-4520 (Telephone Number) STATE OF Georgia COUNTY OF Coweta The foregoing instrument was acknowledged before me by means of ® physical presence or ❑ online notarization, this 3rd day of August _ 2020 , by J Erik McMichael , as Attorney-in-Fact Of Great American Insurance Company a Corporation corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: December 10,2022 LC v r :> I p t` t ; r,%, (Signature of Notary Public) S. D4< �j_ Michelle S Deligne �,..,.. ,. ,o i Name: t�y�1`.•� TAf �'�, ` (Legibly Printed) ' =XPIPES Georgia (AFFIX OFFICIAL SEAL) ORI�'+ .; Notary Public, State of: DEC.10,2022 ; Commission No.: NSA r • 13 Construction Services Agreement:Revised 072118(v6) EXHIBIT B-2: PUBLIC PERFORMANCE BOND ITB# 20-7763 Bond No.2161068 Contract No. 20-7763 KNOW ALL MEN BY THESE PRESENTS: That R2T, Inc. , as Principal, and Great American Insurance Company _ as Surety, located at 301 East 14th St., Cincinnati, OH 45202 (Business Address) are held and firmly bound to The Board of County Commissioners of Collier County, FL as Obligee in the sum of Two Million Seven Hundred Fifty Two Thousand Six Hundred Twenty Nine and 00/100 Dollars ($ 2,752,629.00 ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns,jointly and severally. WH REAS, Principal has entered into a contract dated as of the 0 day of kxar 20 _. , with Obligee for NCWR Effluent Filters No. 2 & 3 Equipment Replacement in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract; and 2. Pays Obligee any and all losses,damages, costs and attorneys'fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this B ond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this 3rd day of August , 2020 , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 14 Construction Services Agreement:Revised 072118(v6) ,`` vo N Illrrrr''' 11.2i !No Signed, sealed and delivered PRINCIPAL in the presence of: :'�Oap��+t�.; R2T, Inc. ,�7r7 �yTj' = SEAL = � �,-I� Q i� BY: Witness s as to Principau6 • ' P NAME: ��� %1.��4ORM i``\ ITS: �, ,7.cs, )i._rT' r,llrltlllt". STATE OF '(' -' COUNTY OF c,l- ; ,. i The foregoing instrument was acknowledged before me by means of ® physical presencepen or ❑ online notarization, this 5-4 day of Auto Cr, .i�l 7 T , as V. Pee.sr,)6./.r7— — of 4 77 ,.—"--- , a /R_ r-et•i;x7,.._ corporation, on behalf of the corporation. He/she is personally k as id to me cation an OR hasd (did not) take an oath. My Commission Expires: �.9/.9s-/.90,91 / ((Signature of N,o/tary Public) `�1�Ittttll�� Name: itiatt�ya /�"1Crri:2%4� N• p'i.......MAR�Nj'%, •;.• /v � lib' i S. (Legibly Printed) �OTAgy 91� s (AFFIX OFFICIAL SEALS c; �•— Q Notary Public, State of:r. .GO r;�, �B��G &.L.::: Commission No.: Gu 003 /D9,�1 • o�•:...,g !c,`:• �"',�,GOUN��,0%°, 15 Construction Services Agreement:Revised 072118(v6) C N , ATTEST: SURETY: Great American Insurance Company (Printed Name) 301 East 14th St. Cincinnati, OH 45202 (Business Address) (Authorized Signature) Witnesses as to Surety (Printed Name) OR J ifer Fr, man AS Attorney in Fact (Attach Power of Attorney) J Erik McMichael W esses bie L Hayes (Printed Name) 47 Postal Parkway Newnan, GA 30263 • (Business Address) (800)226-4520 (Telephone Number) STATE OF Georgia COUNTY OF Coweta The foregoing instrument was acknowledged before me by means of ® physical presence or 0 online notarization, this 3rd day of August _ 20 20 , by J Erik McMichael , as Attorney-in-Fact _ of Great American Insurance Company , a Corporation corporation, on behalf of the corporation. He/she is personally known to me OR has produced _ as identification and did (did not) take an oath. My Commission Expires:December 10, 2022 y : < h D Crt tootles/Is, (Signature of Notary Public) 'J'D�� %, Michelle S Deligne cr p (Legibly Printed) ac: ExpIRpS (AFFIX OFFICIAL SEAL}:-c.10,2022 Notary Public, State of: Georgia •• e Pf,B��,G.• .:� Commission No.: N/A C. �4 • 0 '\'GOB%s 16 Construction Services Agreement:Revised 072118(v6) CM-) GREAT AMERICAN INSURANCE COMPANY® Administrative Office: 301 E 4TH STREET • CINCINNATI, OHIO 45202 • 513-369-5000 • FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than FOUR No.0 21343 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY,a corporation organized and existing under and by virtue of the laws of the State of Ohio,does hereby nominate,constitute and appoint the person or persons named below,each individually if more than one is named,its true and lawful attorney-in-fact,for it and in its name,place and stead to execute on behalf of the said Company,as surety,any and all bonds, undertakings and contracts of suretyship,or other written obligations in the nature thereof;provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. Name Address Limit of Power SUZANNE YEATMAN ALL OF ALL JENNIFER S. FREEMAN NEWMAN, GEORGIA $100,000,000 J.ERIK MCMICHAEL MICHELLE DELIGNE This Power of Attorney revokes all previous powers issued on behalf of the attorney(s)-in-fact named above. IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this 23RD day of JULY 2019 Attest GREAT AMERICAN INSU NCE COMPAN 4(_ e 3 /id yaN iY teet9 Assistant Secretary Divisional Senior Vice President STATE OF OHIO,COUNTY OF HAMILTON-ss: MARK VICARIO(877-377-2405) On this 23RD day of JULY 2019 before me personally appeared MARK VICARIO,to me known, being duly sworn,deposes and says that he resides in Cincinnati,Ohio,that he is a Divisional Senior Vice President of the Bond Division of Great American Insurance Company,the Company described in and which executed the above instrument;that he knows the seal of the said Company;that the seal affixed to the said instrument is such corporate seal;that it was so affixed by authority of his office under the By-Laws of said Company,and that he signed his name thereto by like authority. "' Susan A.Koharst o ;! Notary Public,State of Ohio ` a .4.6o� c•=s My Commission Expires 05-16-2020 This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company by unanimous written consent dated June 9,2008. RESOLVED: That the Divisional President,the several Divisional Senior Vice Presidents,Divisional Vice Presidents and Divisonal Assistant Vice Presidents,or any one of them, be and hereby is authorized,from time to time, to appoint one or more Attorneys-in-Fact to execute on behalf of the Company, as surety,any and all bonds,undertakings and contracts of suretyship,or other written obligations in the nature thereof to prescribe their respective duties and the respective limits of their authority;and to revoke any such appointment at any time. RESOLVED FURTHER: That the Company seal and the signature of any of the aforesaid officers and any Secretary or Assistant Secretary of the Company may be affixed bv,facsimile to any power of attorney or certificate of either given for the execution of any bond, undertaking,contract of suretyship, or other written obligation in the nature thereof;such signature and seal when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company,to be valid and binding upon the Company with the same force and effect as though manually affixed. CERTIFICATION I,STEPHEN C.BERAHA,Assistant Secretary of Great American Insurance Company,do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of June 9,2008 have not been revoked and are now in full force and effect. Signed and sealed this 3rd day of August , 2020 . T •••........••• Assistant Secretary S1029AG(07/18} EXHIBIT B-3: INSURANCE REQUIREMENTS The Contractor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Contractor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Contractor waive against each other and the County's separate Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Contractor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Contractors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number/contract number and title. The General Liability Policy provided by Contractor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Contractor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Contractor has any self-insured retentions or deductibles under any of the below listed minimum required coverage, Contractor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be Contractor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Contractor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non-renewal on the part of the insurance carrier or the Contractor. The Contractor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverage or limits received by Contractor from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Contractor hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 17 Construction Services Agreement:Revised 072118(v6) t` Should at any time the Contractor not maintain the insurance coverage(s) required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage(s) and charge the Contractor for such coverage(s) purchased. If Contractor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Contractor under this Agreement or any other agreement between the County and Contractor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage(s) purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverage(s) shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work,the Contractor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Contractor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 18 Construction Services Agreement:Revised 072118(v6) 4'� Collier County Florida Insurance and Bonding Requirements Insurance/ Bond Type Required Limits 1. ❑ Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof of exemption. An application for exemption can be obtained online at https://apps.fldfs.com/bocexempt/ 2. ❑ Employer's Liability $ single limit per occurrence 3. ❑ Commercial General Bodily Injury and Property Damage Liability (Occurrence Form) patterned after the current $ single limit per occurrence, $2,000,000 aggregate for Bodily Injury ISO form Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. ❑ Indemnification To the maximum extent permitted by Florida law, the ContractorNendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the ContractorNendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. 5. ❑Automobile Liability $ Each Occurrence; Bodily Injury& Property Damage, Owned/Non-owned/Hired;Automobile Included 6. ❑ Other insurance as ❑ Watercraft $ Per Occurrence noted: ❑ United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑ Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑Aircraft Liability coverage shall be carried in limits of not less than$5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. $ Per Occurrence ❑ Pollution $ Per Occurrence ❑ Professional Liability $ Per claim &in the aggregate • $1,000,000 per claim and in the aggregate • $2,000,000 per claim and in the aggregate ❑ Project Professional Liability $ Per Occurrence ❑Valuable Papers Insurance $ Per Occurrence 19 Construction Services Agreement:Revised 072118(v6) ❑ Cyber Liability $ Per Occurrence ❑ Technology Errors&Omissions $ Per Occurrence 7. ❑ Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. ❑ Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as"A-"or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders'surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 9. ❑ Consultant shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Consultant shall provide County with certificates of insurance meeting the required insurance provisions. 10. ❑ Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required.This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. 11. ❑ The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12. ❑ Thirty(30) Days Cancellation Notice required. Consultant's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. Name of Firm Date Consultant Signature Print Name Insurance Agency Agent Name Telephone Number 20 Construction Services Agreement:Revised 072118(v6) EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF(COLLIER) STATE OF (FLORIDA) Before me,the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated ,20 for the period from to .This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors,material-men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed,shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits,actions,claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. CONTRACTOR BY: Witness ITS: President DATE: Witness [Corporate Seal] STATE OF COUNTY OF The foregoing instrument was acknowledged before me by means of ❑ physical presence or ❑ online notarization, this day of , 20 by as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not)take an oath. My Commission Expires: (Signature of Notary Public) NAME: (Legibly Printed) Notary Public, State of (AFFIX OFFICIAL SEAL) Commissioner No.: 21 Construction Services Agreement:Revised 072118(v6) EXHIBIT D FORM OF CONTRACT APPLICATION FOR PAYMENT Collier County Board of County Commissioners(the OWNER) or Collier County Water-Sewer Owner's Project Bid No. Manager's Name: Project No. County's Division Name Purchase Order No. Submitted by Contractor Application Date: Representative: Name Contractor's Name& Payment Application No. Address: Original Contract Time: Original Contract Price: $ Revised Contract Time: Total Change Orders to Date: $ Revised Contract Amount: $ Total Value of Work Completed & $ Stored to Date: Retainage @10% $ Retainage @ 10%through [Insert $ through [Insert Date] date] Retainage @ % $ Less Retainage $ after[Insert date] Total Earned Less Retainage $ Less previous payment(s) Percent Work Completed % AMOUNT DUE THIS $ to Date: APPLICATION: Percent Contract Time ok Completed to Date: Liquidated Damages to $ Remaining Contract Balance $ Be Accrued ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances(except such as covered by Bond acceptable to OWNER); (3)all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. Contractor's Name Contractor's Signature: Date: Type Title: Shall be signed by an authorized representative of the Contractor. Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Design Professional's Name: Signature: Date: Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Owner's Project Manager Name: Signature: Date: 22 Construction Services Agreement:Revised 072118(v6) EXHIBIT D(Continued) SCHEDULE OF VALUES Project Name: Project Number: Date: Period To: ITEM DESCRIPTION SCHEDULED WORK COMPLETED STORED TOTAL PERCENT BALANCE 10% _% TOTAL NUMBER VALUE MATERIALS COMPLETED COMPLETE TO FINISH RETAINAGE RETAINAGE RETAINAGE PREVIOUS APPLICATIONS THIS &STORED (reduced rate) WITHHELD THRU DATE SINCE DATE PERIOD TO DATE TOTALS *Explanation for the two columns under Previous Applications:The Thru Date is where you will place all information until the contract is complete unless a release or reduction of retainage issue cot into play. If this happens,all information up to the date of the%change in retainage is placed in the Thru Date column. Information after that date is placed in the Since Date column.This states what has happened since the change in retainage. 23 Construction Services Agreement:Revised 072118(v6) Exhibit D (Continued) Stored Materials Record Formula: A+ B-C- D = E A B C D E Invoice Previously Received Previously Installed Balance To Date Description Supplier Number Received This Period Installed This Period Install 24 Construction Services Agreement:Revised 072118(v6) EXHIBIT E: CHANGE ORDER An electronic data entry form may be found at: http://bccspOl/SiteDirectory/ASD/Purchasind/Forms1/Forms/Default.aspx Change Order Form Contract*: Change#: FurchaseCrder#: Fr oject#: Contract.°OFirm Name: Project Name: Project Manager Name Department: Qiginal COrtract,Work Crcler Amount a kilns!BCC Appf 01E11 Date;Agenda Item W Current BCC Approved Amount Last BCC Atcdroval Date Agenda Itam# Current ContractAni ark Order Amount SAP Contract Expiration Dale(Master) Dollar Anoount of this Change WC I\PO! Total Charge from Original Amount Revised ContractW ork Order Total 5 0.00 #0 IVO! Change f rom Current BCC Approved Amount Cumulative Changes 5 0 0.0 WD IWO! Chang e f rom Current Ativkint Completion Date, Description of the Task(s)Change,and Rationale for the Change Notice to Proceel Original Last Approved Revised Date Dale Completion Data' Date ...ic Ji3S,11 scnanget #of Days Added Select Tasks 0 Add new taalds) 0 Delete task(s) 0 Cha nge task(s) 0 Other iseedadirl Provide a respon se to the following:1.)detailed and specific exp lanationkatio nate of the requested change(e)to the task(s)and/or the additional days added(if requested):2.)why this change was not included in the original contract:and,3.)describe the impact if this change is not processed. Attach additional informator from the Design.Profe.ssor al ardor Contractor if reeced. Prepared by Dale: lProect Mar.ager Name arc Deparlme.n1; Aczeplarce of this Charge Ordershall constitute a rnotricator to cortact.,.work order identified above and w III te subject to all the sante terms and conditions as contained inthe contract work order indicated above,as fully as if the same were staled in this acceptance. The adjustment.if any.to theContract s hall constitae a full and final settlement of any and all claims of the Contractor,Vendor.,COPS ititar4/ Design Professional arising out of or related to 1 he c hange set forth herein,including c taints for impact and delay costs. Accepted by: Date: {Contractor:Vendor Cons talent Design Professional and Name of F rrtn,if proectapplicable) Approved by: Date: (Design Professional and Name of Firm,if pro)ect applicable) Approved by: Date. (Procurement Professional V314,73 1, ...3.t:.V.::::', 25 Construction Services Agreement:Revised 072118(v6) 0 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. Design Professional's Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER And To Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL,and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 26 Construction Services Agreement:Revised 072118(v6) 0,0 RESPONSIBILITIES: OWNER: CONTRACTOR The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20 Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER By: Type Name and Title 27 Construction Services Agreement:Revised 072118(v6) Ct`.0 EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: PO No.: Date: Contractor: The following items have been secured by the for the Project known as and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner(attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As-Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14. Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: (Company Name) (Signature) (Typed Name&Title) By Design Professional: (Firm Name) (Signature) (Typed Name&Title) By Owner: (Department Name) (Signature) (Name&Title) 28 Construction Services Agreement:Revised 072118(v6) EXHIBIT H: GENERAL TERMS AND CONDITIONS 1. INTENT OF CONTRACT DOCUMENTS. 1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and instal led as part of the Work, whether or not called for by the Contract Documents. 2. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work-site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 29 Construction Services Agreement:Revised 072118(v6) 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub-Section 2.2 as the"Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. 3. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be 30 Construction Services Agreement:Revised 072118(v6) co limited to the hours of 7 a.m. to 7 p.m., Monday through Saturday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.4 Contractor shall submit its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 4.5 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re-submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is 31 Construction Services Agreement:Revised 072118(v6) '1 stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent (50%) completion subject to the guidelines set forth in Florida Statute 255.078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub-subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub-subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non- payment under the legal doctrine of "'aches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 32 Construction Services Agreement:Revised 072118(v6) 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non-liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5.3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off-set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 33 Construction Services Agreement:Revised 072118(v6) CAP 7. SUBMITTALS AND SUBSTITUTIONS. 7.1 Contractor shal I carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will 34 Construction Services Agreement:Revised 072118(v6) record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub-Contractor's personnel; 8.1.4 The number of Contractor's and Sub-Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1.8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features 35 Construction Services Agreement:Revised 072118(v6) (e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The "As-Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As-Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 9. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material-men, as well as coordinating its Work with all 36 Construction Services Agreement:Revised 072118(v6) work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work 37 Construction Services Agreement:Revised 072118(v6) Directive. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub-subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or sub-subcontractor for field and home office overhead is included in the markups noted above. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight (48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pend ency of any Claim. 38 Construction Services Agreement:Revised 072118(v6) 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit B-3 to the Agreement. 39 Construction Services Agreement:Revised 072118(v6) Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit B-3. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet- based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: • Commodity based procurement where no services are provided. • Where the requirem ent for the affidavit is waived by the Board of County Commissioners Contractors/Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Contractor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Contractors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the Bidder/Contractor does not comply with providing both the acceptable E-Verify evidence and the executed affidavit the bidder's /Contractor's proposal may be deemed non- responsive. 40 Construction Services Agreement:Revised 072118(v6) Additionally, Contractors shall require all subcontracted Contractors to use the E-Verify system for all purchases not covered under the "Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (E-Verify) program visit the following website: http://www.dhs.gov/E-Verifv. It shall be the Contractor's responsibility to familiarize themselves with all rules and regulations governing this program. Contractor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2.3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies when the Contractor is acquiring permits. Owner will not be obligated to pay for any permits obtained by Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 41 Construction Services Agreement:Revised 072118(v6) 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default of the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or(10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s)within seven (7)calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials,equipment, supplies, and other items therefore or re-letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 42 Construction Services Agreement:Revised 072118(v6) 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below . 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager 43 Construction Services Agreement:Revised 072118(v6) shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch-list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch-list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: (1) Receipt of Contractor's Final Application for Payment. (2) The Release and Affidavit in the form attached as Exhibit C. (3) Consent of surety to final payment. (4) Receipt of the final payment check list. (5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers,fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 44 Construction Services Agreement:Revised 072118(v6) 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re-inspection fees and costs; to the extent such re-inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight(8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shal I as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non-defective Work. Contractor shall bear all direct, indirect and consequential 45 Construction Services Agreement:Revised 072118(v6) costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstructio n. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall 46 Construction Services Agreement:Revised 072118(v6) include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit A-1 is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.B, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened dam age, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 47 Construction Services Agreement:Revised 072118(v6) CAO 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, 48 Construction Services Agreement:Revised 072118(v6) CA.) Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5.7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5.9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor sh all attend a pre-construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or 49 Construction Services Agreement:Revised 072118(v6) Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre-construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right-of-Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.net/purchasing. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof,which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of 50 Construction Services Agreement:Revised 072118(v6) the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness,access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be "qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self-performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub-subcontractor performing any portion of the Work, as well as maintain a log of all such licenses.All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of 51 Construction Services Agreement:Revised 072118(v6) Owner upon termination of Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third-party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its sub- subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on-site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor (including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be caused by Owner or Design Professional or attributable to Owner or Design Professional and including claims based on breach of contract or negligence, shall be an extension of its contract time. 33.6.2 In the event of a change in the work, the Subcontractor's claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus no more than 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub-subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner, and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 52 Construction Services Agreement:Revised 072118(v6) 34.1.3 Shop Drawing Submittal/Approval Logs 34.1.4 Equipment Purchase/Delivery Logs 34.1.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 34.1.10 Equipment Costs 34.1.11 Cost Proposal Request 34.1.12 Payment Request Records 34.1.13 Meeting Minutes 34.1.14 Cost-Estimates 34.1.15 Bulletin Quotations 34.1.16 Lab Test Reports 34.1.17 Insurance Certificates and Bonds 34.1.18 Contract Changes 34.1.19 Permits 34.1.20 Material Purchase Delivery Logs 34.1.21 Technical Standards 34.1.22 Design Handbooks 34.1.23 "As-Built" Marked Prints 34.1.24 Operating & Maintenance Instruction 34.1.25 Daily Progress Reports 34.1.26 Monthly Progress Reports 34.1.27 Correspondence Files 34.1.28 Transmittal Records 34.1.29 Inspection Reports 34.1.30 Punch Lists 34.1.31 PMIS Schedule and Updates 34.1.32 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the presentation requirements and format. Presentations may include, but not be limited to, the following information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shal I be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County 53 Construction Services Agreement:Revised 072118(v6) under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four(4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e-mail (DL-FMOPScollierqov.net)whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of $500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the Contractor is responsible for all costs. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A"project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid & Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing /will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48-hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials/ petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 54 Construction Services Agreement:Revised 072118(v6) 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision-making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 55 Construction Services Agreement:Revised 072118(v6) CM) Detail by Entity Name Page 1 of 2 Florida Department of State DIVISION OF CORPORATIONS J!v!�ltl!I rJf .:� • r9 �'��1 iu Tic r rre of Florida ireblilt Department of State / Division of Corporations / Search Records / Search by Entity Name/ Detail by Entity Name Foreign Profit Corporation R2T, INC. Filing Information Document Number F05000003590 FEI/EIN Number 20-2835149 Date Filed 06/09/2005 State GA Status ACTIVE Principal Address 500 Village Square Crossing Suite 202 Palm Beach Gardens, FL 33410 Changed: 10/22/2018 Mailing Address 580 W.CROSSVILLE ROAD SUITES 101-102 ROSWELL, GA 30075 Changed: 02/07/2008 Registered Agent Name&Address CT Corporation System 1200 South Pine Island Rd Plantation, FL 33324 Name Changed:02/14/2017 Address Changed: 02/14/2017 Officer/Director Detail Name&Address Title CPD AJY, KIMBERLY 1841 Peeler Rd Unit C Atlanta, GA 30338 http://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=Entity... 8/5/2020 Detail by Entity Name Page 2 of 2 Title VPST AJY,GEORGE 580 W CROSSVILLE ROAD SUITE 101 ROSWELL,GA 30075 Annual Reports Report Year Filed Date 2018 03/08/2018 2019 02/15/2019 • 2020 03/18/2020 Document Images 03/18/2020—ANNUAL REPORT View image in PDF format 02/15/2019--ANNUAL REPORT View image in PDF format 10/22/2018—AMENDED ANNUAL REPORT View image in PDF format 03/08/2018—ANNUAL REPORT View image in PDF format 02/14/2017—ANNUAL REPORT View image in PDF format 02/12/2016--ANNUAL REPORT View image in PDF format 02/20/2015—ANNUAL REPORT View image in PDF format 03/14/2014—ANNUAL REPORT View image in PDF format 01/07/2013—ANNUAL REPORT View image in PDF format 01/04/2012—ANNUAL REPORT View image in PDF format 01/03/2011--ANNUAL REPORT View image in PDF format 01/04/2010—ANNUAL REPORT View image in PDF format 01/08/2009—ANNUAL REPORT View image in PDF format 02/07/2008--ANNUAL REPORT View image in PDF format 01/05/2007—ANNUAL REPORT View image in PDF format 02/05/2006—ANNUAL REPORT View image in PDF format 06/09/2005--Foreign Profit View image in PDF format Florida Department or State,Division of Corporations http://s earch.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=Entity... 8/5/2020 Client#:653633 R2TINC1 ACORDTM CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 8/03/2020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder in lieu of such endorsement(s). PRODUCER NAME: CONTACT Amber Zell J Smith Lanier&Co Newnan PHONE 770-683-1000 FAX 770-683-1010 (A/C,No,Ext): (A/C,No): P.O.Box 71429 MAILS; azell@,jsmithlanier.com ADDRES 47 Postal Parkway INSURER(S)AFFORDING COVERAGE NAIL# Newnan,GA 30271-1429 INSURER A Transportation Insurance 20494 INSURED INSURER B:Continental Casualty Company 20443 R2T, Inc. INSURER c:Houston Casualty Company _ 42374 580 W.Crossville Road INSURER D:Continental Insurance Company 35289 Suites 101-102 INSURER E: Roswell, GA 30075 INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSR WVD POLICY NUMBER (MM/DDIYYYY) (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY X X 5084059559 07/28/2020 07/28/2021 EACH OCCURRENCE $1,000,000 CLAIMS-MADE X OCCUR PREMISES(Ea occurrence) $100,000 MED EXP(Any one person) $15,000 PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 X POLICY JECOT LOC PRODUCTS-COMP/OPAGG $2,000,000 OTHER: e D AUTOMOBILE LIABILITY X X 2095995258 07/28/2020 07/28/2021 E accideDfSINGLE LIMIT $1,000,000 X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ v AUTOS ONLY X AUTOS ONLY (Per accident) A X UMBRELLA LIAB X OCCUR 5084059478 07/28/2020 07/28/2021 EACH OCCURRENCE $6,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $6,000,000 DED X RETENTION$10000 $ B WORKERS COMPENSATION X 5084059514 07/28/2020 07/28/2021 X STATUTE ERH AND EMPLOYERS'LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE Y I N E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? Y N/A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 C Professional/Poll HCC1966919 07/28/2020 07/28/2021 $2,000,000/$2,000,000 A Rented/Leased Eqp 5084059559 07/28/2020 07/28/2021 $250,000 Max Per Item D Hired/Phys Damage 2095995258 07/28/2020 07/28/2021 $1,000/Comp/Coll Ded DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) (GL)Additional Insured/Primary and Non-Contributory and Waiver of Subrogation per Forms CNA748580115 and CNA750590115. (CAU)Additional Insured/Primary and Non-Contributory per Form CA20481013 and CNA63359GA0512. (CAU)Waiver of Subrogation per Form CA04441013 (WC)Waiver of Subrogation per Form WC0003130484 (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Colliers County Board of County THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Commissioners ACCORDANCE WITH THE POLICY PROVISIONS. 3295 Tamiami Trail E Naples, FL 34112 AUTHORIZED REPRESENTATIVE I7j lc 1 tom.' - - Kac 4•`' ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 2 The ACORD name and logo are registered marks of ACORD #S6288158/M5828760 JJSXT DESCRIPTIONS (Continued from Page 1) Re: Project#20-7763-Job NCWRF Effluent Filters No 2&3 Equipment Replacement(BL) Full certificate holder: Colliers County Board of County Commissioners, or Board of County Commissioners in Collier County, Collier County Government, or Collier County 30 Day Notice as per Insurer specific form to be listed upon policy issuance SAGITTA 25.3(2016/03) 2 of 2 #S6288158/M 5828760 CNA CNA PARAMOUNT Primary and Noncontributory - Other Insurance Condition Endorsement This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART It is understood and agreed that the condition entitled Other insurance is amended to add the following: Primary And Noncontributory Insurance Notwithstanding anything to the contrary, this insurance is primary to and will not seek contribution from any other insurance available to an additional insured under this policy provided that: a. the additional insured is a named insured under such other insurance;and b. the Named Insured has agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. All other terms and conditions of the Policy remain unchanged. This endorsement,which forms a part of and is for attachment to the Policy issued by the designated Insurers, takes effect on the effective date of said Policy at the hour stated in said Policy, unless another effective date is shown below, and expires concurrently with said Policy. (-0 0 0 0 MNIMMIN 0 0 0 0 Oryp CNA74987XX{1-15) Policy No: SO84059559 Page 1 of 1 Endorsement No: 14 AMERICAN CASUALTY CO OF READING,PA Effective Date: 07/28/201.9 Insured Name: R2T, INC. CopyrIght CNA All Rights Reserved Includes copyrighted material at Insurance Services mica,Inc.,with its permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability • Extension Endorsement It is understood and agreed that this endorsement amends the COMMERCIAL GENERAL LIABILITY COVERAGE PART as follows. If any other endorsement attached to this policy amends any provision also amended by this endorsement. then that other endorsement controls with respect to such provision. and the changes made by this endorsement with respect to such provision do not apply. TABLE OF CONTENTS 1. Additional Insureds 2. Additional Insured-Primary And Non-Contributory To Additional Insured's Insurance 3. Additional Insured—Extended Coverage 4. Boats 5. Bodily Injury—Expanded Definition 6. Broad Knowledge of Occurrence;Notice of Occurrence 7. Broad Named Insured _ 8. Contractual Liability—Railroads 9. Estates, Legal Representatives and Spouses 10. Expected Or Intended Injury—Exception for Reasonable Force 11. General Aggregate Limits of Insurance—Per Location 12. In Rem Actions 13. Incidental Health Care Malpractice Coverage 14. Joint Ventures/Partnership/Limited Liability Companies 15. Legal Liability—Damage To Premises 16. Liquor Liability 17. Medical Payments a 18. Non-owned Aircraft Coverage 19. Non-owned Watercraft 20. Personal And Advertising Injury—Discrimination or Humiliation 21. Personal And Advertising Injury-Contractual Liability 22. Property Damage—Elevators 23. Retired Partners,Members,Directors And Employees 24. Supplementary Payments 25. Unintentional Failure To Disclose Hazards 26. Waiver of Subrogation—Blanket 27. Wrap-Up Extension: OCIP,CCIP or Consolidated(Wrap-Up)Insurance Programs CNA74858XX(1-15) Policy No: 9,,,:n59559 Page 1 of 18 T?ANSPO TATION INSURANCE COMPANY Insured Name:R2T, INC. Capynyl:CNA All Ri$is Reserves. Includes wpyrrylred melee i u'Insuruiwe Services U'!ice.Inc..wrJ!ix wri nssun. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 1. ADDITIONAL INSUREDS a. WHO IS AN INSURED is amended to include as an Insured any person or organization described in paragraphs A. through I. below whom a Named Insured is required to add as an additional insured on this Coverage Part under a written contract or written agreement, provided such contract or agreement: (1) is currently in effect or becomes effective during the term of this Coverage Part;and (2) was executed prior to. (a) the bodily injury or property damage;or (b) the offense that caused the personal and advertising injury, for which such additional insured seeks coverage. b. However, subject always to the terms and conditions of this policy, including the limits of insurance, the Insurer will not provide such additional insured with: (1) a higher limit of insurance than required by such contract or agreement;or (2) coverage broader than required by such contract or agreement,and in no event broader than that described by the applicable paragraph A.through I.below. Any coverage granted by this endorsement shall apply only to the extent permissible by law. A. Controlling Interest Any person or organization with a controlling interest in a Named Insured, but only with respect to such person or organization's liability for bodily injury,property damage or personal and advertising injury arising out of: 1. such person or organization's financial control of a Named Insured;or 2. premises such person or organization owns, maintains or controls while a Named Insured leases or occupies such premises; provided that the coverage granted by this paragraph does not apply to structural alterations,new construction or demolition operations performed by,on behalf of,or for such additional insured. B. Co-owner of Insured Premises A co-owner of a premises co-owned by a Named Insured and covered under this insurance but only with respect to such co-owner's liability for bodily injury, property damage or personal and advertising injury as co-owner of such premises. C. Engineers,Architects or Surveyors Engaged By You An architect, engineer or surveyor engaged by the Named Insured, but only with respect to liability for bodily injury,property damage or personal and advertising injury caused in whole or in part by the Named Insured's acts or omissions,or the acts or omissions of those acting on the Named Insured's behalf: a. in connection with the Named Insured's premises;or b. in the performance of the Named Insured's ongoing operations. But the coverage hereby granted to such additional insureds does not apply to bodily injury, property damage or personal and advertising injury arising out of the rendering of or failure to render any professional services by,on behalf of,or for the Named Insured,including but not limited to: CNA74858XX(1-15) Policy No: 5084059559 Page 2 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA All Rips Reserved. Includes copyrighted materiel a'Insurance Services Office,Inc.,with is permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 1. the preparing, approving. or failing to prepare or approve, maps. shop drawings, opinions, reports, surveys, field orders,change orders or drawings and specifications; or 2. supervisory, inspection.architectural or engineering activities. D. Lessor of Equipment Any person or organization from whom a Named Insured leases equipment, but only with respect to liability for bodily injury, property damage or personal and advertising injury caused, in whole or in part, by the Named Insured's maintenance, operation or use of such equipment, provided that the occurrence giving rise to such bodily injury. property damage or the offense giving rise to such personal and advertising injury takes place prior to the termination of such lease. E. Lessor of Land Any person or organization from whom a Named Insured leases land but only with respect to liability for bodily injury, property damage or personal and advertising injury arising out of the ownership, maintenance or use of such land, provided that the occurrence giving rise to such bodily injury. property damage or the offense giving rise to such personal and advertising injury takes place prior to the termination of such lease. The coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by,on behalf of.or for such additional insured. F. Lessor of Premises An owner or lessor of premises leased to the Named Insured, or such owner or lessor's real estate manager,but only with respect to liability for bodily injury,property damage or personal and advertising injury arising out of the ownership. maintenance or use of such part of the premises leased to the Named Insured,and provided that the occurrence giving rise to such bodily injury or property damage,or the offense giving rise to such personal and advertising injury, takes place prior to the termination of such lease. The coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by, on behalf of,or for such additional insured. G. Mortgagee, Assignee or Receiver A mortgagee, assignee or receiver of premises but only with respect to such mortgagee, assignee or receiver's liability for bodily injury. property damage or personal and advertising injury arising out of the Named Insured's ownership. maintenance, or use of a premises by a Named Insured. The coverage granted by this paragraph does not apply to structural alterations, new construction or demolition operations performed by.on behalf of,or for such additional insured. H. State or Governmental Agency or Subdivision or Political Subdivisions—Permits A state or governmental agency or subdivision or political subdivision that has issued a permit or authorization but only with respect to such state or governmental agency or subdivision or political subdivision's liability for bodily injury,property damage or personal and advertising injury arising out of 1. the following hazards in connection with premises a Named Insured owns, rents, or controls and to which this insurance applies: a. the existence, maintenance, repair, construction, erection, or removal of advertising signs, awnings, canopies. cellar entrances, coal holes, driveways, manholes, marquees. hoistaway openings. sidewalk vaults,street banners,or decorations and similar exposures.or b. the construction,erection,or removal of elevators;or c. the ownership. maintenance or use of any elevators covered by this insurance;or CNA74858XX(1-15) Policy No: 5084059559 Page 3 of 18 TPANSPORTATION INSURANCE COMPANY Insured Name: P,2T, INC. Cdpyngh;CNA AN Rights Reserved. Includes copyrighted material o'Insurance Services Olice.Inc..wth i.s permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 2. the permitted or authorized operations performed by a Named Insured or on a Named Insured's behalf. The coverage granted by this paragraph does not apply to: a. Bodily injury,property damage or personal and advertising injury arising out of operations performed for the state or governmental agency or subdivision or political subdivision;or b. Bodily injury or property damage included within the products-completed operations hazard. With respect to this provision's requirement that additional insured status must be requested under a written contract or agreement, the Insurer will treat as a written contract any governmental permit that requires the Named Insured to add the governmental entity as an additional insured. I. Trade Show Event Lessor 1. With respect to a Named Insured's participation in a trade show event as an exhibitor, presenter or displayer, any person or organization whom the Named Insured is required to include as an additional insured, but only with respect to such person or organization's liability for bodily injury, property damage or personal and advertising injury caused by: a. the Named Insured's acts or omissions;or b. the acts or omissions of those acting on the Named Insured's behalf, in the performance of the Named Insured's ongoing operations at the trade show event premises during the trade show event. 2. The coverage granted by this paragraph does not apply to bodily injury or property damage included within the products-completed operations hazard. 2. ADDITIONAL INSURED-PRIMARY AND NON-CONTRIBUTORY TO ADDITIONAL INSURED'S INSURANCE The Other Insurance Condition in the COMMERCIAL GENERAL LIABILITY CONDITIONS Section is amended to add the following paragraph: If the Named Insured has agreed in writing in a contract or agreement that this insurance is primary and non- contributory relative to an additional insured's own insurance, then this insurance is primary,and the Insurer will not seek contribution from that other insurance. For the purpose of this Provision 2., the additional insured's own insurance means insurance on which the additional insured is a named insured. Otherwise, and notwithstanding anything to the contrary elsewhere in this Condition, the insurance provided to such person or organization is excess of any other insurance available to such person or organization. 3. ADDITIONAL INSURED—EXTENDED COVERAGE When an additional insured is added by this or any other endorsement attached to this Coverage Part,WHO IS AN INSURED is amended to make the following natural persons Insureds. If the additional insured is. a. An individual,then his or her spouse is an Insured; b. A partnership or joint venture,then its partners,members and their spouses are Insureds; c. A limited liability company,then its members and managers are Insureds;or d. An organization other than a partnership, joint venture or limited liability company, then its executive officers, directors and shareholders are Insureds; CNA74858XX(1-15) Policy No: 5084059559 Page 4 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:P.2T, INC. Copyright CNA AM Rights Reserved. Includes copyrighted material d insurance Services Office,Inc.,with Its permission CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement but only with respect to locations and operations covered by the additional insured endorsement's provisions,and only with respect to their respective roles within their organizations. Please see the ESTATES, LEGAL REPRESENTATIVES, AND SPOUSES provision of this endorsement for additional coverage and restrictions applicable to spouses of natural person Insureds. 4. BOATS Under COVERAGES, Coverage A — Bodily Injury And Property Damage Liability, the paragraph entitled Exclusions is amended to add the following additional exception to the exclusion entitled Aircraft, Auto or Watercraft: This exclusion does not apply to: Any watercraft owned by the Named Insured that is less than 30 feet long while being used in the course of the Named Insured's inspection or surveying work. 5. BODILY INJURY—EXPANDED DEFINITION Under DEFINITIONS,the definition of bodily injury is deleted and replaced by the following; Bodily injury means physical injury,sickness or disease sustained by a person, including death, humiliation, shock, mental anguish or mental injury sustained by that person at any time which results as a consequence of the physical injury.sickness or disease. 6. BROAD KNOWLEDGE OF OCCURRENCE/NOTICE OF OCCURRENCE Under CONDITIONS,the condition entitled Duties in The Event of Occurrence,Offense, Claim or Suit is amended to add the following provisions: A. BROAD KNOWLEDGE OF OCCURRENCE The Named Insured must give the Insurer or the Insurer's authorized representative notice of an occurrence, offense or claim only when the occurrence,offense or claim is known to a natural person Named Insured, to a partner, executive officer,manager or member of a Named Insured,or to an employee designated by any of the A above to give such notice. B. NOTICE OF OCCURRENCE The Named Insured's rights under this Coverage Part will not be prejudiced if the Named Insured fails to give the Insurer notice of an occurrence, offense or claim and that failure is solely due to the Named Insured's reasonable belief that the bodily injury or property damage is not covered under this Coverage Part. However, the Named Insured shall give written notice of such occurrence,offense or claim to the Insurer as soon as the Named Insured is aware that this insurance may apply to such occurrence,offense or claim. 7. BROAD NAMED INSURED WHO IS AN INSURED is amended to delete its Paragraph 3.in its entirety and replace it with the following: main 3. Pursuant to the limitations described in Paragraph 4. below, any organization in which a Named Insured has management control: a. on the effective date of this Coverage Part;or b. by reason of a Named Insured creating or acquiring the organization during the policy period, me. qualifies as a Named Insured, provided that there is no other similar liability insurance, whether primary, = contributory,excess,contingent or otherwise,which provides coverage to such organization,or which would have CNA74858XX(1-15) Policy No: 5084 59559 Page 5 of 18 TR.ANSPOT:TATION INSURANCE COMPANY Insured Name:R2T, INC. Capyrigti CNA AI Rig Reserved. Includes ccpyrighted materiel of Insurance Services Office.hc..vet)rs permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement provided coverage but for the exhaustion of its limit, and without regard to whether its coverage is broader or narrower than that provided by this insurance. But this BROAD NAMED INSURED provision does not apply to. (a) any partnership, limited liability company or joint venture;or (b) any organization for which coverage is excluded by another endorsement attached to this Coverage Part. For the purpose of this provision,management control means: A. owning interests representing more than 50% of the voting, appointment or designation power for the selection of a majority of the Board of Directors of a corporation;or B. having the right, pursuant to a written trust agreement, to protect, control the use of,encumber or transfer or sell property held by a trust. 4. With respect to organizations which qualify as Named Insureds by virtue of Paragraph 3.above, this insurance does not apply to: a. bodily injury or property damage that first occurred prior to the date of management control, or that first occurs after management control ceases;nor b. personal or advertising injury caused by an offense that first occurred prior to the date of management control or that first occurs after management control ceases. 5. The insurance provided by this Coverage Part applies to Named Insureds when trading under their own names or under such other trading names or doing-business-as names (dba) as any Named Insured should choose to employ. 8. CONTRACTUAL LIABILITY—RAILROADS With respect to operations performed within 50 feet of railroad property,the definition of insured contract is replaced by the following. Insured Contract means: a. A contract for a lease of premises. However,that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire to premises while rented to a Named Insured or temporarily occupied by a Named Insured you with permission of the owner is not an insured contract; b. A sidetrack agreement; c. Any easement or license agreement; d. An obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality; e. An elevator maintenance agreement; f. That part of any other contract or agreement pertaining to the Named Insured's business (including an indemnification of a municipality in connection with work performed for a municipality) under which the Named Insured assumes the tort liability of another party to pay for bodily injury or property damage to a third person or organization. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement. Paragraph f.does not include that part of any contract or agreement: CNA74858XX(1-15) Policy No: 508405955D Page 6 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA Al Rights Reserved. Includes copyrighted materiel of Insurance Services Omce,kit..with is permission CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement (1) That indemnifies an architect,engineer or surveyor for injury or damage arising out of. (a) Preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders,change orders or drawings and specifications;or (b) Giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage; (2) Under which the Insured, if an architect, engineer or surveyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in(1) above and supervisory, inspection,architectural or engineering activities. 9. ESTATES,LEGAL REPRESENTATIVES,AND SPOUSES The estates, executors, heirs, legal representatives, administrators, trustees, beneficiaries and spouses of any natural person Insured or living trust shall also be insured under this policy; provided, however, coverage is afforded to such estates, executors, heirs, legal representatives, administrators, trustees, beneficiaries and spouses only for claims arising solely out of their capacity or status as such and, in the case of a spouse, where such claim seeks damages from marital community property, jointly held property or property transferred from such natural person Insured to such spouse. No coverage is provided for any act, error or omission of an estate, heir, legal representative,or spouse outside the scope of such person's capacity or status as such, provided, however, that the spouse of a natural person Named Insured,and the spouses of members or partners of joint venture or partnership Named Insureds are Insureds with respect to such spouses'acts, errors or omissions in the conduct of the Named Insured's business. 10. EXPECTED OR INTENDED INJURY—EXCEPTION FOR REASONABLE FORCE Under COVERAGES, Coverage A — Bodily Injury And Property Damage Liability, the paragraph entitled Exclusions is amended to delete the exclusion entitled Expected or Intended Injury and replace it with the following: This insurance does not apply to: Expected or Intended Injury Bodily injury or property damage expected or intended from the standpoint of the Insured. This exclusion does not apply to bodily injury or property damage resulting from the use of reasonable force to protect persons or property. § 11. GENERAL AGGREGATE LIMITS OF INSURANCE-PER LOCATION A. A separate Location General Aggregate Limit.equal to the amount of the General Aggregate Limit, is the most the Insurer will pay for the sum of: 1. All damages under Coverage A,except damages because of bodily injury or property damage included in the products-completed operations hazard;and 2. All medical expenses under Coverage C, that arise from occurrences or accidents which can be attributed solely to ongoing operations at that location. ommuop Such payments shall not reduce the General Aggregate Limit shown in the Declarations,nor the Location General MIMS Aggregate Limit of any other location. B. All: MEE 1. Damages under Coverage B, regardless of the number of locations involved; = CNA74858XX(1-15) Policy No: 5n84n59559 Page 7 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:P.2T, INC. Copynght CNA AN Rigr*s Reserved. Includes copyrighted material of Insurance Services Orrice,Inc..wrh i:s permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 2. Damages under Coverage A, caused by occurrences which cannot be attributed solely to ongoing operations at a single location, except damages because of bodily injury or property damage included in the products-completed operations hazard;and 3. Medical expenses under Coverage C caused by accidents which cannot be attributed solely to ongoing operations at a single location, will reduce the General Aggregate Limit shown in the Declarations. C. For the purpose of this GENERAL AGGREGATE LIMITS OF INSURANCE - PER LOCATION Provision. "location"means: 1. a premises the Named Insured owns or rents;or 2. a premises not owned or rented by any Named Insured at which the Named Insured is performing operations pursuant to a contract or written agreement. If operations at such a location have been discontinued and then restarted, or if the authorized parties deviate from plans, blueprints, designs, specifications or timetables, the location will still be deemed to be the same location. For the purpose of determining the applicable aggregate limit of insurance, premises involving the same or connecting lots, or premises whose connection is interrupted only by a street, roadway,waterway or right-of-way of a railroad shall be considered a single location. D. The limits shown in the Declarations for Each Occurrence, for Damage To Premises Rented To You and for Medical Expense continue to apply, but will be subject to either the Location General Aggregate Limit or the General Aggregate Limit,depending on whether the occurrence can be attributed solely to ongoing operations at a particular location. E. When coverage for liability arising out of the products-completed operations hazard is provided, any payments for damages because of bodily injury or property damage included in the products-completed operations hazard, regardless of the number of locations involved, will reduce the Products-Completed Operations Aggregate Limit shown in the Declarations. F. The provisions of LIMITS OF INSURANCE not otherwise modified by this GENERAL AGGREGATE LIMITS OF INSURANCE-PER LOCATION Provision shall continue to apply as stipulated. 12. IN REM ACTIONS A quasi in rem action against any vessel owned or operated by or for the Named Insured, or chartered by or for the Named Insured,will be treated in the same manner as though the action were in personam against the Named Insured. 13. INCIDENTAL HEALTH CARE MALPRACTICE COVERAGE Solely with respect to bodily injury that arises out of a health care incident. A. Under COVERAGES,Coverage A—Bodily Injury And Property Damage Liability,the Insuring Agreement is amended to replace Paragraphs 1.b.(1)and 1.b.(2)with the following. b. This insurance applies to bodily injury provided that the professional health care services are incidental to the Named Insured's primary business purpose,and only if: (1) such bodily injury is caused by an occurrence that takes place in the coverage territory (2) the bodily injury first occurs during the policy period. All bodily injury arising from an occurrence will be deemed to have occurred at the time of the first act, error,or omission that is part of the occurrence; and CNA74858XX(1-15) Policy No: 5084059559 Page 8 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA Al Rights Reserved. Includes capynghted materiel d Insurance Services Office,Inc..with its pecn ssim. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement B. Under COVERAGES, Coverage A — Bodily Injury And Property Damage Liability, the paragraph entitled Exclusions is amended to: i. add the following to the Employers Liability exclusion: This exclusion applies only if the bodily injury arising from a health care incident is covered by other liability insurance available to the Insured (or which would have been available but for exhaustion of its limits). II. delete the exclusion entitled Contractual Liability and replace it with the following: This insurance does not apply lo: Contractual Liability the Insured's actual or alleged liability under any oral or written contract or agreement, including but not limited to express warranties or guarantees. iii. to add the following additional exclusions: This insurance does not apply to: Discrimination any actual or alleged discrimination, humiliation or harassment, including but not be limited to claims based on an individual's race, creed, color, age,gender, national origin, religion,disability, marital status or sexual orientation. Dishonesty or Crime Any actual or alleged dishonest,criminal or malicious act,error or omission. Medicare/Medicaid Fraud any actual or alleged violation of law with respect to Medicare, Medicaid, Tricare or any similar federal,state $ or local governmental program. Services Excluded by Endorsement Any health care incident for which coverage is excluded by endorsement. C. DEFINITIONS is amended to: i. add the following definitions: Health care incident means an act, error or omission by the Named Insured's employees or volunteer workers in the rendering of: MEE a. professional health care services on behalf of the Named Insured or b. Good Samaritan services rendered in an emergency and for which no payment is demanded or received. Professional health care services means any health care services or the related furnishing of food, beverages, medical supplies or appliances by the following providers in their capacity as such but solely to the extent they are duly licensed as required: a. Physician; MOOR =,=== CNA74858XX(1-15) Policy No: 5084059559 Page 9 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyngte CNA AM Rights Reserved. Includes copyrighted materiel o'Insurance Services Office,Inc..with rs permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement b. Nurse; c. Nurse practitioner; d. Emergency medical technician; e. Paramedic; f. Dentist; g. Physical therapist; h. Psychologist; i. Speech therapist; j. Other allied health professional;or Professional health care services does not include any services rendered in connection with human clinical trials or product testing. ii. delete the definition of occurrence and replace it with the following. Occurrence means a health care Incident.All acts, errors or omissions that are logically connected by any common fact,circumstance,situation, transaction, event,advice or decision will be considered to constitute a single occurrence; iii. amend the definition of Insured to: a. add the following: the Named Insured's employees are Insureds with respect to: (1) bodily injury to a co-employee while in the course of the co-employee's employment by the Named Insured or while performing duties related to the conduct of the Named Insured's business;and (2) bodily injury to a volunteer worker while performing duties related to the conduct of the Named insured's business; when such bodily injury arises out of a health care incident. the Named Insured's volunteer workers are Insureds with respect to: (1) bodily injury to a co-volunteer worker while performing duties related to the conduct of the Named Insured's business;and (2) bodily injury to an employee while in the course of the employee's employment by the Named Insured or while performing duties related to the conduct of the Named Insured's business; when such bodily injury arises out of a health care incident. b. delete Subparagraphs(a),(b),(c)and(d)of Paragraph 2.a.(1)of WHO IS AN INSURED. D. The Other Insurance condition is amended to delete Paragraph b.(1) in its entirety and replace it with the following Other Insurance CNA74858XX(1-15) Policy No: 5084059559 Page 10 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:P2T, INC. Copyright CNA Al Rights Reserved. Includes capytighted materiel d Insurance Services Office,Inc..with its permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement b. Excess Insurance (1) To the extent this insurance applies, it is excess over any other insurance, self insurance or risk transfer instrument, whether primary, excess, contingent or on any other basis, except for insurance purchased specifically by the Named Insured to be excess of this coverage. 14. JOINT VENTURES/PARTNERSHIP I LIMITED LIABILITY COMPANIES A. Past Joint Ventures,Partnerships,Limited Liability Companies The following is added to WHO IS AN INSURED: If the Named Insured was a joint venturer, partner, or member of a limited liability company and such joint venture, partnership or limited liability company terminated prior to or during the policy period, such Named Insured is an Insured with respect to its interest in such joint venture, partnership or limited liability company but only to the extent that: a. any offense giving rise to personal and advertising injury occurred prior to such termination date, and the personal and advertising injury arising out of such offense,first occurred after such termination date; b. the bodily injury or property damage first occurred after such termination date;and c. there is no other valid and collectible insurance purchased specifically to insure the partnership,joint venture or limited liability company. if the joint venture, partnership or limited liability company is or was insured under a consolidated (wrap-up) insurance program, then such insurance will always be considered valid and collectible for the purpose of paragraph c.above. But this provision will not serve to exclude bodily injury, property damage or personal and advertising injury that would otherwise be covered under the Architects, Engineers And Surveyors General Liability Extension Endorsement provision entitled WRAP-UP EXTENSION: OCIP, CCIP, OR CONSOLIDATED (WRAP-UP) INSURANCE PROGRAMS. Please see that provision for the definition of consolidated(wrap-up)insurance program. B. Participation In Current Professional Joint Ventures The following is added to WHO IS AN INSURED. The Named Insured is also an Insured for participation in a current joint venture that is not named on the ec Pa P 1 Declarations,but only if such joint venture meets all of the following criteria: a. Each and every one of the Named Insured's co-venturers are architectural, engineering or surveying firms only;and b. There is no other valid and collectible insurance purchased specifically to insure the joint venture. However,the Named Insured is an Insured only for the conduct of such Named Insured's business within such a joint venture. The Named Insured is not insured for liability arising out of the acts or omissions of other co- venturers,nor of their partners,members or employees. IMITE C. WHO IS AN INSURED is amended to delete its last paragraph and replace it with the following: Except as provided under this Architects, Engineers And Surveyors General Liability Extension Endorsement or by the attachment of another endorsement(if any), no person or organization is an Insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations. simamm CNA74858XX(1-15) Policy No: 5084nr9 5:) Page 11 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:P2T, INC. Copynght CNA All Rights Reserved. Includes copyrighted materiel of Insurance Services Office.Inc..with is permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 15. LEGAL LIABILITY — DAMAGE TO PREMISES I ALIENATED PREMISES / PROPERTY IN THE NAMED INSURED'S CARE,CUSTODY OR CONTROL A. Under COVERAGES, Coverage A — Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete exclusion j.Damage to Property in its entirety and replace it with the following: This insurance does not apply to: j. Damage to Property Property damage to: (1) Property the Named Insured owns,rents,or occupies, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to anothers property; (2) Premises the Named Insured sells, gives away or abandons, if the property damage arises out of any part of those premises; (3) Property loaned to the Named Insured; (4) Personal property in the care,custody or control of the Insured; (5) That particular part of real property on which the Named Insured or any contractors or subcontractors working directly or indirectly on the Named Insured's behalf are performing operations, if the property damage arises out of those operations;or (6) That particular part of any property that must be restored, repaired or replaced because your work was incorrectly performed on it. Paragraphs(1),(3)and(4)of this exclusion do not apply to property damage(other than damage by fire)to premises rented to the Named Insured or temporarily occupied by the Named Insured with the permission of the owner, nor to the contents of premises rented to the Named Insured for a period of 7 or fewer consecutive days.A separate limit of insurance applies to Damage To Premises Rented To You as described in LIMITS OF INSURANCE. Paragraph(2)of this exclusion does not apply if the premises are your work. Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement. Paragraph (6) of this exclusion does not apply to properly damage included in the products-completed operations hazard. Paragraphs(3)and(4)of this exclusion do not apply to property damage to: i. tools,or equipment the Named Insured borrows from others,nor ii. other personal property of others in the Named Insured's care,custody or control while being used in the Named Insured's operations away from any Named Insured's premises. However,the coverage granted by this exception to Paragraphs(3)and(4)does not apply to: a. property at a job site awaiting or during such property's installation,fabrication,or erection; b. property that is mobile equipment leased by an Insured; CNA74858XX(1-15) Policy No: 5084059559 Page 12of18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA Al Rights Reserved. tndudes capynghted material ce Insurance Services Office,Inc.,wifi'.s permission, CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement c. property that is an auto,aircraft or watercraft; d. property in transit,or e. any portion of property damage for which the Insured has available other valid and collectible insurance,or would have such insurance but for exhaustion of its limits, or but for application of one of its exclusions. A separate limit of insurance and deductible apply to such property of others. See LIMITS OF INSURANCE as amended below. B. Under COVERAGES, Coverage A — Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete its last paragraph and replace it with the following: Exclusions c. through n. do not apply to damage by fire to premises while rented to a Named Insured or temporarily occupied by a Named Insured with permission of the owner, nor to damage to the contents of premises rented to a Named Insured for a period of 7 or fewer consecutive days. A separate limit of insurance applies to this coverage as described in LIMITS OF INSURANCE. C. The following paragraph is added to LIMITS OF INSURANCE: Subject to 5.above,525,000 is the most the Insurer will pay under Coverage A for damages arising out of any one occurrence because of the sum of all property damage to borrowed tools or equipment, and to other personal property of others in the Named Insured's care, custody or control, while being used in the Named Insured's operations away from any Named Insured's premises. The Insurer's obligation to pay such property damage does not apply until the amount of such property damage exceeds$1,000. The Insurer has the right but not the duty to pay any portion of this 51,000 in order to effect settlement. If the Insurer exercises that right, the Named Insured will promptly reimburse the Insurer for any such amount. D. Paragraph 6.,Damage To Premises Rented To You Limit,of LIMITS OF INSURANCE is deleted and replaced by the following: 6. Subject to Paragraph 5.above, (the Each Occurrence Limit), the Damage To Premises Rented To You Limit is the most the Insurer will pay under Coverage A for damages because of property damage to any one premises while rented to the Named Insured or temporarily occupied by the Named Insured with the permission of the owner, including contents of such premises rented to the Named Insured for a period of 7 or fewer consecutive days.The Damage To Premises Rented To You Limit is the greater of a. 5500,000;or b. The Damage To Premises Rented To You Limit shown in the Declarations. E. Paragraph 4.b.(1Xa)(ii)of the Other Insurance Condition is deleted and replaced by the following: (ii) That is property insurance for premises rented to the Named Insured,for premises temporarily occupied by the Named Insured with the permission of the owner, or for personal property of others in the Named Insured's care,custody or control; NZ 16. LIQUOR LIABILITY Under COVERAGES, Coverage A — Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete the exclusion entitled Liquor Liability. This LIQUOR LIABILITY Provision does not apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part. CNA74858XX(1-15) Policy No: 5f84n59,5a Page 13 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA Al RigNs Reserved. Includes copyrighted material o'Insurance Services Office,Inc..with it3 permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 17. MEDICAL PAYMENTS A. LIMITS OF INSURANCE is amended to delete Paragraph 7. (the Medical Expense Limit)and replace it with the following. 7. Subject to Paragraph 5. above (the Each Occurrence Limit), the Medical Expense Limit is the most the Insurer will pay under Coverage C for all medical expenses because of bodily injury sustained by any one person. The Medical Expense Limit is the greater of. (1) S15,000 unless a different amount is shown here: $N,NNN,NNN,NNN; or (2) the amount shown in the Declarations for Medical Expense Limit. B. Under COVERAGES, the Insuring Agreement of Coverage C — Medical Payments is amended to replace Paragraph 1.a.(3)(b)with the following: (b) The expenses are incurred and reported to the Insurer within three years of the date of the accident;and 18. NON-OWNED AIRCRAFT Under COVERAGES, Coverage A — Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended as follows The exclusion entitled Aircraft,Auto or Watercraft is amended to add the following: This exclusion does not apply to an aircraft not owned by any Named Insured,provided that: 1. the pilot in command holds a currently effective certificate issued by the duly constituted authority of the United States of America or Canada,designating that person as a commercial or airline transport pilot; 2. the aircraft is rented with a trained,paid crew to the Named Insured;and 3. the aircraft is not being used to carry persons or property for a charge. 19. NON-OWNED WATERCRAFT Under COVERAGES, Coverage A — Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended to delete subparagraph (2) of the exclusion entitled Aircraft, Auto or Watercraft, and replace it with the following This exclusion does not apply to: (2) a watercraft that is not owned by any Named Insured, provided the watercraft is: (a) less than 75 feet long;and (b) not being used to carry persons or property for a charge. 20. PERSONAL AND ADVERTISING INJURY—DISCRIMINATION OR HUMILIATION A. Under DEFINITIONS,the definition of personal and advertising injury is amended to add the following tort: Discrimination or humiliation that results in injury to the feelings or reputation of a natural person. B. Under COVERAGES, Coverage B — Personal and Advertising Injury Liability, the paragraph entitled Exclusions is amended to: 1. delete the Exclusion entitled Knowing Violation Of Rights Of Another and replace it with the following: CNA74858XX(1-15) Policy No: 5084059559 Page 14 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA All Flights Reserved. krdudes capynghted material d Insurance Services Office,Inc.,with is permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement This insurance does not apply to: Knowing Violation of Rights of Another Personal and advertising injury caused by or at the direction of the Insured with the knowledge that the act would violate the rights of another and would inflict personal and advertising injury.This exclusion shall not apply to discrimination or humiliation that results in injury to the feelings or reputation of a natural person, but only if such discrimination or humiliation is not done intentionally by or at the direction of: (a) the Named Insured;or (b) any executive officer, director, stockholder, partner, member or manager (if the Named Insured is a limited liability company)of the Named Insured. 2. add the following exclusions: This insurance does not apply to: Employment Related Discrimination discrimination or humiliation directly or indirectly related to the employment, prospective employment, past employment or termination of employment of any person by any Insured. Premises Related Discrimination discrimination or humiliation arising out of the sale, rental, lease or sub-lease or prospective sale, rental, lease or sub-lease of any room,dwelling or premises by or at the direction of any Insured. Notwithstanding the above, there is no coverage for fines or penalties levied or imposed by a governmental entity because of discrimination. The coverage provided by this PERSONAL AND ADVERTISING INJURY —DISCRIMINATION OR HUMILIATION Provision does not apply to any person or organization whose status as an Insured derives solely from Provision 1.ADDITIONAL INSURED of this endorsement;or attachment of an additional insured endorsement to this Coverage Part. 21. PERSONAL AND ADVERTISING INJURY-CONTRACTUAL LIABILITY A. Under COVERAGES, Coverage B —Personal and Advertising Injury Liability, the paragraph entitled Exclusions is amended to delete the exclusion entitled Contractual Liability. B. Solely for the purpose of the coverage provided by this PERSONAL AND ADVERTISING INJURY - LIMITED CONTRACTUAL LIABILITY provision, the following changes are made to the section entitled SUPPLEMENTARY PAYMENTS—COVERAGES A AND B: 1. Paragraph 2.d.is replaced by the following: d. The allegations in the suit and the information the Insurer knows about the offense alleged in such suit are such that no conflict appears to exist between the interests of the Insured and the interests of the indemnitee; 2. The first unnumbered paragraph beneath Paragraph 2.f.2 b is deleted and replaced bythe following: 9 PhO( )� P So long as the above conditions are met, attorney's fees incurred by the Insurer in the defense of that indemnitee, necessary litigation expenses incurred by the Insurer, and necessary litigation expenses incurred CNA74858XX(1-15) Policy No: 5084059559 Page 15 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Capyrgta CNA AM Rights Reserved. includes copyrighted material o'Insurance Services Office.Inc..wi71 its permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement by the indemnitee at the Insurer's request will be paid as defense costs. Such payments will not be deemed to be damages for personal and advertising injury and will not reduce the limits of insurance. C. This PERSONAL AND ADVERTISING INJURY -LIMITED CONTRACTUAL LIABILITY Provision does not apply if Coverage B —Personal and Advertising Injury Liability is excluded by another endorsement attached to this Coverage Part This PERSONAL AND ADVERTISING INJURY - CONTRACTUAL LIABILITY Prov;slon does no: apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part. 22. PROPERTY DAMAGE—ELEVATORS A. Under COVERAGES. Coverage A — Bodily Injury and Property Damage Liability, the paragraph entitled Exclusions is amended such that the Damage to Your Product Exclusion and subparagraphs(3), (4) and (6)of the Damage to Property Exclusion do not apply to property damage that results from the use of elevators. B. Solely for the purpose of the coverage provided by this PROPERTY DAMAGE — ELEVATORS Provision, the Other Insurance conditions is amended to add the following paragraph: This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis that is Property insurance covering property of others damaged from the use of elevators. 23. RETIRED PARTNERS,MEMBERS, DIRECTORS AND EMPLOYEES WHO IS INSURED is amended to nclude as Insureds natural persons who are retired partners, members, directors or employees, but only for bodily injury, property damage or personal and advertising injury that results from services performed for the Named Insured under the Named Insured's direct supervision. All limitations that apply to employees and volunteer workers also apply to anyone qualifying as an Insured under this Provision. 24. SUPPLEMENTARY PAYMENTS The section entitled SUPPLEMENTARY PAYMENTS—COVERAGES A AND B is amended as follows. A. Paragraph 1.b.is amended to delete the$250 limil shown for the cost of bail bonds and replace it with a S5,000. limit;and B. Paragraph 1.d. is amended to delete the limit of S250 shown for daily loss of earnings and replace it with a S1,000. lint t 25. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS f me Named Insured unintentionally fails to disclose all existing hazards at the inception date of the Named Insured's Coverage Part,the Insurer will not deny coverage under this Coverage Part because of such failure. 26. WAIVER OF SUBROGATION -BLANKET Under CONDITIONS,the condition entitled Transfer Of Rights Of Recovery Against Others To Us is amended to add the following The Insurer waives any right of recovery the Insurer may have against any person or organization because of payments the Insurer makes for injury or damage arising out of: 1. the Named Insured's ongoing operations:or 2. your work included in the products-completed operations hazard However,this waiver applies only when the Named Insured has agreed in writing to waive such rights of recovery in a written contract or written agreement, and only if such contract or agreement: CNA74858XX(1-15) Policy No: 5084.059559 Page 16 of 18 T?ANS PORT ATION INSURANCE COI,:RANI' Insured Name: PIT, INC. Copyright CNA All Rights Reserved. Includes cepyngh:ed material d Insuarx:e Services Office.Inc.,wrti rs permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement 1. is in effect or becomes effective during the term of this Coverage Part;and 2. was executed prior to the bodily injury, property damage or personal and advertising injury giving rise to the claim. 27. WRAP-UP EXTENSION:OCIP,CCIP,OR CONSOLIDATED(WRAP-UP)INSURANCE PROGRAMS Note: The following provision does not apply to any public construction project in the state of Oklahoma, nor to any construction project in the state of Alaska, that is not permitted to be insured under a consolidated (wrap-up) insurance program by applicable state statute or regulation. If the endorsement EXCLUSION— CONSTRUCTION WRAP-UP is attached to this policy, or another exclusionary endorsement pertaining to Owner Controlled Insurance Programs (O.C.I.P.) or Contractor Controlled Insurance Programs(C.C.I.P.)is attached,then the following changes apply: A. The following wording is added to the above-referenced endorsement: With respect to a consolidated (wrap-up) insurance program project in which the Named Insured is or was involved, this exclusion does not apply to those sums the Named Insured become legally obligated to pay as damages because of. 1. Bodily injury,property damage,or personal or advertising injury that occurs during the Named Insured's ongoing operations at the project, or during such operations of anyone acting on the Named Insured's behalf; nor 2. Bodily injury or property damage included within the products-completed operations hazard that arises out of those portions of the project that are not residential structures. B. Condition 4.Other Insurance is amended to add the following subparagraph 4.b.(1)(c): This insurance is excess over. (c) Any of the other insurance whether primary,excess,contingent or any other basis that is insurance available to the Named Insured as a result of the Named Insured being a participant in a consolidated (wrap-up) insurance program, but only as respects the Named Insured's involvement in that consolidated(wrap-up) x insurance program. C. DEFINITIONS is amended to add the following definitions: Consolidated (wrap-up) insurance program means a construction, erection or demolition project for which the prime contractor/project manager or owner of the construction project has secured general liability insurance covering some or all of the contractors or subcontractors involved in the project, such as an Owner Controlled Insurance Program (O.C.I.P.)or Contractor Controlled Insurance Program(C.C.I.P.). Residential structure means any structure where 301)/0 or more of the square foot area is used or is intended to be used for human residency,including but not limited to. 1. single or multifamily housing, apartments, condominiums, townhouses, co-operatives or planned unit iams developments;and OM- 2. the common areas and structures appurtenant to the structures in paragraph 1. (including pools, hot tubs, EEE detached garages,guest houses or any similar structures). However,when there is no individual ownership of units, residential structure does not include military housing, college/university housing or dormitories, long term care facilities, hotels or motels. Residential structure also does not include hospitals or prisons. CNA74858XX(1-15) Policy No: Sn84059559 Page 17 of 18 Ti=ANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. CpYr CNA Al Rights Reserved. Includes copyrighted materiel or hsurance Services Office,Inc.,will hs permission. CNA CNA PARAMOUNT Architects, Engineers and Surveyors General Liability Extension Endorsement This WRAP-UP EXTENSION:OCIP, CCIP, OR CONSOLIDATED(WRAP-UP)INSURANCE PROGRAMS Provision does not apply to any person or organization who otherwise qualifies as an additional insured on this Coverage Part All other terms and conditions of the Policy remain unchanged. This endorsement,which forms a part of and is for attachment to the Policy issued by the designated Insurers,takes effect on the effective date of said Policy at the hour stated in said Policy, unless another effective date is shown below, and expires concurrently with said Policy. CNA74858XX(1-15) Policy No: 5084059559 Page 18 of 18 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyright CNA Ail Rights Reserved. Includes copyrighted nisterial d Insurance Services Office,Inc.wit its permission. CNA CNA PARAMOUNT General Aggregate Limit - Per Project Endorsement This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is understood and agreed as follows: I. For each single construction or service project away from premises the Named Insured owns or rents, a separate Project General Aggregate Limit,equal to the amount of the General Aggregate Limit shown in the Declarations, is the most the Insurer will pay for the sum of. A. all damages under Coverage A,except damages because of bodily injury or property damage included in the products-completed operations hazard;and B. all medical expenses under Coverage C: that arise from occurrences or accidents which can be attributed solely to ongoing operations at that project. Such payments shall not reduce the General Aggregate Limit shown in the Declarations,nor the Project General Aggregate Limit applicable to any other project. II. All: A. damages under Coverage B,regardless of the number of locations or projects involved; B. damages under Coverage A,caused by occurrences which cannot be attributed solely to ongoing operations at a single project, except damages because of bodily injury or property damage included in the products- completed operations hazard;and C. medical expenses under Coverage C, caused by accidents which cannot be attributed solely to ongoing operations at a single project, will reduce the General Aggregate Limit shown in the Declarations. III. The limits shown in the Declarations for Each Occurrence, for Damage To Premises Rented To You and for Medical Expense continue to apply, but will be subject to either the Project General Aggregate Limit or the General Aggregate Limit shown in the Declarations,depending on whether the occurrence can be attributed solely to ongoing operations at a particular project. IV. When coverage for liability arising out of the products-completed operations hazard is provided, any payments for damages because of bodily injury or property damage included in the products-completed operations hazard will reduce the Products-Completed Operations Aggregate Limit shown in the Declarations, regardless of the number of projects involved. E V. If a single construction or service project away from premises owned by or rented to the Named Insured has been abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications or timetables,such project will still be deemed to be the same project. VI. The provisions of LIMITS OF INSURANCE not otherwise modified by this endorsement shall continue to apply as stipulated. red All other terms and conditions of the Policy remain unchanged. VESA This endorsement,which forms a part of and is for attachment to the Policy issued by the designated Insurers,takes effect - on the effective date of said Policy at the hour stated in said Policy, unless another effective date is shown below, and - expires concurrently with said Policy. - CNA75061XX(1-15) Policy No: 50R4ff 9559 Page 1 of 1 TRANSPORTATION INSURANCE COMPANY Insured Name:P.2T, INC. Copyright CNA AM Rights Reserved. Includes copyrighted material o'Insurance Set.,,.ca Cdfice,Inc..writ its permission. CNA CNA PARAMOUNT Blanket Additional Insured - Owners, Lessees or Contractors -with Products-Completed Operations Coverage Endorsement This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART It is understood and agreed as follows: I. The WHO IS AN INSURED section is amended to add as an Insured any person or organization whom the Named Insured is required by written contract to add as an additional insured on this coverage part, including any such person or organization, if any. specifically set forth on the Schedule attachment to this endorsement. However, such person or organization is an Insured only with respect to such person or organization's liability for: A. unless paragraph B.below applies, 1. bodily injury,property damage,or personal and advertising injury caused in whole or in part by the acts or omissions by or on behalf of the Named Insured and in the performance of such Named Insured's ongoing operations as specified in such written contract:or 2. bodily injury or property damage caused in whole or in part by your work and included in the products- completed operations hazard,and only if a. the written contract requires the Named Insured to provide the additional insured such coverage;and b. this coverage part provides such coverage. B. bodily injury,property damage,or personal and advertising injury arising out of your work described in such written contract,but only if. 1. this coverage part provides coverage for bodily injury or property damage included within the products completed operations hazard;and 2. the written contract specifically requires the Named Insured to provide additional insured coverage under the 11-85 or 10-01 edition of CG2010 or the 10-01 edition of CG2037. II. Subject always to the terms and conditions of this policy, including the limits of insurance, the Insurer will not provide such additional insured with: A. coverage broader than required by the written contract;or B. a higher limit of insurance than required by the written contract. III. The insurance granted bythis endorsement to the additional insured does not I to bodilyinjury, ro e apply property rtY damage,or personal and advertising injury arising out of: A. the rendering of, or the failure to render, any professional architectural, engineering, or surveying services, including: 1. the preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders,change orders or drawings and specifications;and 2. supervisory,inspection,architectural or engineering activities;or B. any premises or work for which the additional insured is specifically listed as an additional insured on another endorsement attached to this coverage part. IV. Notwithstanding anything to the contrary in the section entitled COMMERCIAL GENERAL LIABILITY CONDITIONS, the Condition entitled Other Insurance, this insurance is excess of all other insurance available to the additional insured whether on a primary,excess,contingent or any other basis. However, if this insurance is required by written CNA75079XX(1-15) Policy No: 50R4050559 Page 1 of 2 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. Copyngrx CNA Atl Rights Reserved. Includes copyrighted materiel of kisurence services Office,Inc.,with is pemrssicn. CNA CNA PARAMOUNT Blanket Additional Insured - Owners, Lessees or Contractors - with Products-Completed Operations Coverage Endorsement contract to be primary and non-contributory, this insurance will be primary and non-contributory relative solely to insurance on which the additional insured is a named insured. V. Solely with respect to the insurance granted by this endorsement, the section entitled COMMERCIAL GENERAL LIABILITY CONDITIONS is amended as follows: The Condition entitled Duties In The Event of Occurrence,Offense, Claim or Suit is amended with the addition of the following: Any additional insured pursuant to this endorsement will as soon as practicable: 1. give the Insurer written notice of any claim,or any occurrence or offense which may result in a claim; 2. except as provided in Paragraph IV. of this endorsement, agree to make available any other insurance the additional insured has for any loss covered under this coverage part; 3. send the Insurer copies of all legal papers received, and otherwise cooperate with the Insurer in the investigation,defense,or settlement of the claim;and 4. tender the defense and indemnity of any claim to any other insurer or self insurer whose policy or program applies to a loss that the Insurer covers under this coverage part. However, if the written contract requires this insurance to be primary and non-contributory, this paragraph (4) does not apply to insurance on which the additional insured is a named insured. The Insurer has no duty to defend or indemnify an additional insured under this endorsement until the Insurer receives written notice of a claim from the additional insured. VI. Solely with respect to the insurance granted by this endorsement, the section entitled DEFINITIONS is amended to add the following definition: Written contract means a written contract or written agreement that requires the Named Insured to make a person or organization an additional insured on this coverage part,provided the contract or agreement: A. is currently in effect or becomes effective during the term of this policy;and B. was executed prior to: 1. the bodily injury or property damage;or 2. the offense that caused the personal and advertising Injury for which the additional insured seeks coverage. Any coverage granted by this endorsement shall apply solely to the extent permissible by law. All other terms and conditions of the Policy remain unchanged. This endorsement,which forms a part of and is for attachment to the Policy issued by the designated Insurers,takes effect on the effective date of said Policy at the hour stated in said Policy, unless another effective date is shown below, and expires concurrently with said Policy. CNA75079XX(1-15) Policy No: 5084059559 Page 2 of 2 TRANSPORTATION INSURANCE COMPANY Insured Name:R2T, INC. copyright CNA AN Rights Reserved. Includes copyrighted materiel d Insurance services Office,Inc.,will its permission, POLICY NUMBER: COMMERCIAL AUTO CA 04 44 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following. AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement,the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: PST, SCHEDULE Name(s)Of Person(s)Or Organization(s): ANY PERSON OR ORGANIZATION FOR WHOM OR WHICH YOU ARE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT TO OBTAIN THIS WAIVER FROM US. YOU MUST AGREE TO THAT REQUIREMENT PRIOR TO LOSS. Information required to complete this Schedule. if riot shown above,will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule. but only to the extent that subrogation is waived prior to the "accident" PI or the "loss" under a contract with that person or organization. CA 04 44 10 13 Copyright, Insurance Services Office. Inc, 2011 Page 1 of 1 A63359GA CNA CN(Ed.05112) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CONTRACTORS EXTENDED COVERAGE ENDORSEMENT - BUSINESS AUTO PLUS - GEORGIA This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM I. LIABILITY COVERAGE name, with your permission, while performing duties related to the conduct of your business. A. Who Is An Insured 'Policy,' as used in this provision A. Who Is An The following is added to Section II, Paragraph Insured, includes those policies that were in force A.1.,Who Is An Insured: on the inception date of this Coverage Form but: 1. a. Any incorporated entity of which the 1. Which are no longer in force;or Named Insured owns a majority of the voting stock on the date of inception of 2. Whose limits have been exhausted. this Coverage Form; provided that, B. Bail Bonds and Loss of Earnings b. The insurance afforded by this provision Section II, Paragraphs A.2. (2) and A.2. (4) are A.1. does not apply to any such entity revised as follows: that is an 'insured' under any other liability'policy' providing'auto"coverage. 1. In a.(2), the limit for the cost of bail bonds is changed from$2,000 to$5,000;and 2. Any organization you newly acquire or form, other than a limited liability company, 2. In a.(4), the limit for the loss of earnings is partnership or joint venture, and over which changed from $250 to$500 a day. you maintain majority ownership interest. C. Fellow Employee The insurance afforded by this provision A.2.: Section II, Paragraph B.5 does not apply. a. Is effective on the acquisition or formation Such coverage as is afforded by this provision C. date, and is afforded only until the end of is excess over any other collectible insurance. the policy period of this Coverage Form, or the next anniversary of its inception II. PHYSICAL DAMAGE COVERAGE date,whichever is earlier. A. Glass Breakage — Hitting A Bird Or Animal — b. Does not apply to: Falling Objects Or Missiles 2 (1) 'Bodily injury' or 'property damage" The following is added to Section III, Paragraph caused by an 'accident' that A.3.: occurred before you acquired or With respect to any covered'auto,' any deductible formed the organization;or shown in the Declarations will not apply to glass (2) Any such organization that is an breakage if such glass is repaired, in a manner 'insured" under any other liability acceptable to us,rather than replaced. 'policy'providing'auto"coverage. B. Transportation Expenses 3. Any person or organization that you are required by a written contract to name as an Section III, Paragraph A.4.a. is revised, with additional insured is an 'insured' but only with respect to transportation expense incurred by you, respect to their legal liability for acts or to provide: omissions of a person, who qualifies as an a. $60 per day, in lieu of$20;subject to 'insured' under Section II — Who Is An Insured and for whom Liability Coverage is b. $1,800 maximum, in lieu of$600. afforded under this policy. If required by C. Loss of Use Expenses written contract, this insurance will be primary and non-contributory to insurance on which Section III, Paragraph A.4.b. is revised, with the additional insured is a Named Insured. respect to loss of use expenses incurred by you, to provide: 4. An "employee" of yours is an "insured' while operating an "auto' hired or rented under a a. $1,000 maximum, in lieu of$600. contract or agreement in that "employee's" CNA63359GA Copyright,CNA corporation,2oo0. Page 1 of 3 (Ed.05/12) Includes copyr material of the Insurance Services Office used with its permission. CNA63359GA (Ed.05/12) D. Hired"Autos" d. A S100 per occurrence deductible applies to The following is added to Section III. Paragraph the coverage provided by this provision. A.: III. Drive Other Car Coverage—Executive Officers 5. Hired"Autos" The following is added to Sections II and III: If Physical Damage coverage is provided under 1. Any "auto" you don't own, hire or borrow is a this policy, and such coverage does not extend to covered 'auto' for Liability Coverage while being Hired Autos, then Physical Damage coverage is used by, and for Physical Damage Coverage extended to: while in the care,custody or control of, any of your a. Any covered "auto' you lease, hire, rent 'executive officers,'except: or borrow without a driver; and a. An "auto" owned by that "executive officer" or b. Any covered "auto" hired or rented by a member of that person's household; or your 'employee"without a driver, under a b. An "auto' used by that 'executive officer" contract in that individual "employee's" while working in a business of selling, name, with your permission, while servicing, repairing or parking"autos." performing duties related to the conduct of your business. Such Liability and/or Physical Damage Coverage as is afforded by this provision. c. The most we will pay for any one "accident' or 'loss' is the actual cash (1) Equal to the greatest of those coverages value, cost of repair, cost of replacement afforded any covered'auto"; and or S75,000, whichever is less, minus a (2) Excess over any other collectible $500 deductible for each covered auto. insurance. No deductible applies to 'loss' caused by fire or lightning. 2. For purposes of this provision, "executive officer" means a person holding any of the officer d. The physical damage coverage as is positions created by your charter, constitution, by- provided by this provision is equal to the laws or any other similar governing document, physical damage coverage(s) provided on and, while a resident of the same household, your owned"autos.' includes that person's spouse. e. Such physical damage coverage for hired Such 'executive officers° are "insureds" while "autos"will: using a covered'auto'described in this provision. (1) Include loss of use, provided it is the IV. BUSINESS AUTO CONDITIONS consequence of an 'accident' for which the Named Insured is legally A. Duties in The Event Of Accident, Claim,Suit Or liable, and as a result of which a Loss monetary loss is sustained by the The following is added to Section IV, Paragraph leasing or rental concern. A.2.a.: (2) Such coverage as is provided by this (4) Your 'employees" may know of an provision will be subject to a limit of "accident" or "loss." This will not mean $750 per'accident.' that you have such knowledge, unless E. Airbag Coverage such 'accident" or "loss" is known to you or if you are not an individual, to any of The following is added to Section III, Paragraph your executive officers or partners or your B.3.: insurance manager. The accidental discharge of an airbag shall not be The following is added to Section IV, Paragraph considered mechanical breakdown. A.2.b.: F. Electronic Equipment (6) Your "employees' may know of Section III, Paragraphs B.4.c and B.4.d. are documents received concerning a claim deleted and replaced by the following: or'suit.' This will not mean that you have such knowledge, unless receipt of such c. Physical Damage Coverage on a covered documents is known to you or if you are "auto" also applies to 'loss' to any not an individual,to any of your executive permanently installed electronic equipment officers or partners or your insurance including its antennas and other accessories manager. CNA63359GA Copyright,CNA corporation,2000. Page 2 of 3 (Ed.05/12) includes copyr ghted material of the Insurance Services Office used with its permission. CNA63359GA (Ed.05/12) B. Transfer Of Rights Of Recovery Against Others D. Other Insurance To Us The following is added to Section IV, Paragraph The following is added to Section IV, Paragraph B.5.: A.5. Transfer Of Rights Of Recovery Against Others To Us: Regardless of the provisions of Paragraphs 5.a. and 5.d. above, the coverage provided by this We waive any right of recovery we may have, policy shall be on a primary non-contributory because of payments we make for injury or basis. This provision is applicable only when damage, against any person or organization for required by a written contract. That written whom or which you are required by written contract must have been entered into prior to contract or agreement to obtain this waiver from 'Accident'or'Loss." us. E. Policy Period,Coverage Territory This injury or damage must arise out of your Section IV, Paragraph B. 7.(5).(a). is revised to activities under a contract with that person or organization. provide: You must agree to that requirement prior to an a. 45 days of coverage in lieu of 30 days. 'accident'or'loss." V. DEFINITIONS C. Concealment,Misrepresentation or Fraud Section V. Paragraph C. is deleted and replaced by The following is added to Section IV, Paragraph the following: 8.2.: 'Bodily injury'means bodily injury,sickness or disease Your failure to disclose all hazards existing on the date sustained by a person, including mental anguish, of inception of this Coverage Form shall not prejudice mental injury or death resulting from any of these. you with respect to the coverage afforded provided such failure or omission is not intentional. I CNA63359GA copyright,CNA Corporation,2000. Page 3 of 3 (Ed.05/12) Includes copyr gilled material of the Insurance Services Office used with its permission. POLICY NUMBER: COMMERCIAL AUTO CA 20 48 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following. AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement,the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s)or organization(s)who are"insureds" for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured; R2T, INC. SCHEDULE Name Of Person(s)Or Organization(s): Any person or organization whom you are required to add as an additional insured on this policy under a written contract or written agreement. You must agree to these contracts prior to the date of loss. ISOMMOMMI 2 2 Information required to complete this Schedule,if not shown above,will be shown in the Declarations. MINIM Each person or organization shown in the Schedule is an Autos Liability Coverage in the Business Auto and Motor 11111111111111 "insured" for Covered Autos Liability Coverage. but only Carrier Coverage Forms and Paragraph D.2.of Section I to the extent that person or organization qualifies as an - Covered Autos Coverages of the Auto Dealers "insured" under the Who Is An Insured provision Coverage Form. contained in Paragraph A.1. of Section II - Covered CA 20 48 10 13 Copyright. Insurance Services Office, Inc., 2011 Page 1 of 1 WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 13 (Ed.4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule ANY PERSON OR ORGANIZATION 'WITH WHOM YOU AGREE IN WRITTING TO WAIVE YOUR RICHT TO RECOVER AGAINST THEM. YOU MUST AGREE TO THIS WAIVER PRIOR TO THE DATE OF LOSS. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective Policy No. Endorsement No. Insured Premium$ Insurance Company Countersigned by WC 00 03 13 (Ed.4-84) Copyright 1983 National Council on Compensation Insurance.