Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Agenda 07/14/2020 Item #11K (Award ITB #20-7752 to Haskins, Inc.)
07/14/2020 EXECUTIVE SUMMARY Recommendation to award Invitation to Bid ("ITB") No. 20-7752, "Hickory Road Water Main Improvements" (Project Number 70129), to Haskins, Inc., in the amount of $1,377,246.50, and authorize the Chairman to sign the attached agreement. OBJECTIVE: Meet demand, stay in compliance, and serve customers efficiently by providing a compliant and reliable potable water system to Collier County Water -Sewer District customers. CONSIDERATIONS: The proposed scope of work under Project No. 70129, "Vanderbilt Beach Road Water Main (US 41 - Airport Road)" is consistent with the FY2020 Budget approved by the Board on September 19, 2019, as amended. The Hickory Road Water Main Improvements represents a portion of the total Vanderbilt Beach Road Water Main. The Hickory Road Water Main Improvements project consists of installing a new water main on Hickory Road, Carica Road, and Vanderbilt Beach Road from a point west of Tamiami Trail North (US 41) & Vanderbilt Beach Road to Goodlette-Frank Road. This project is being completed to remove and replace the aging cast iron water main on Carica Road and Hickory Road from Goodlette-Frank Road to Tamiami Trail North (US 41). The cast iron water main, installed in the late 1970's, has reached the end of its useful life and needs to be replaced. This project will also provide additional potable and firefighting water reliability to the northern portions of the Collier County Water District. On April 2, 2020, the Procurement Services Department released ITB No. 20-7752 to 28,694 contractors for the Hickory Road Water Main Improvements project. Contractors downloaded one hundred twenty- six (126) bid packages, and the County received fifteen (15) bids by the May 5, 2020 deadline. The bid tabulation results (Attachment No. 1) for Bid 20-7752, "Hickory Road Water Main Improvements are shown below. Company Name City County State Base Bid Base Bid Responsive/ Submitted with Math Responsible Correction Cougar Fort Lee FL $1,350,400.69 Yes/No Contracting LLC. Myers Haskins, Inc. Bonita Lee FL $1,360,746.50 1,377,246.50 Yes/Yes Springs Thompkins Lehigh Lee FL $1,395,362.75 Yes/Yes Contracting Inc. Acres PWC Joint Fort Lee FL $1,405,129.00 Yes/Yes Venture, LLC Myers Douglas N. Naples Collier FL $1,426,975.00 Yes/Yes Higgins, Inc Packet Pg. 763 07/14/2020 Company Name City County State Base Bid Base Bid Responsive/ Submitted with Math Responsible Correction GT General Coral Broward FL $1,446,392.00 Yes/Yes Contractors Springs R.P. Utility & Hialeah Miami -Dade FL $1,499,342.24 Yes/Yes Excavation Corp. Andrew Sitework Fort Lee FL $1,574,660.00 Yes/Yes LLC Myers Mitchell & Stark Naples Collier FL $1,600,682.12 Yes/Yes Const Co. Inc. Metro Equipment Miami Miami -Dade FL $1,686,712.00 Yes/Yes Service Inc. Intercounty Pompano Broward FL $1,743,465.00 1,742,942.00 Yes/Yes Engineering Inc. Beach Quality Enterprises Naples Collier FL $1,802,843.00 Yes/Yes USA, Inc. Strickler Bros Fort Lee FL $1,869,400.00 Yes/Yes Underground, Inc. Myers American Pipeline Miami Miami -Dade FL $1,920,775.00 Yes/Yes Construction, LLC. Coastal Concrete Fort Lee FL $1,970,533.00 Yes/Yes Products LLC Myers Upon review of the bid submission staff found Cougar Contracting, LLC not responsible because it did not meet the minimum required experience (Contractor Qualifications - Exhibit J - Technical Specs) of the bid documents. Additionally, both Haskins and InterCounty Engineering had rounding/formula errors in their bids. Based on the foregoing, staff is recommending award to the second lowest, responsive/responsible bidder: Haskins, Inc. ("Haskins") (Attachment No. 4). Haskins's bid is 26 percent lower than the engineer's cost opinion (Attachment No. 2). In its June 17, 2020 engineering recommendation letter (Attachment No. 3), design professional Johnson Engineering, Inc., recommends awarding the contract to Haskins, who has a satisfactory performance and warranty record on previous, similar, utility -related projects. The total project cost incorporates $100,000 for owner -directed allowance for work related to unforeseen conditions including, but not limited to, conflicts with existing facilities not reflected in record drawings and modifications or repairs resulting from unforeseen utility work associated with this project. Inclusion of the Allowance as part of the Contract Price is not a guarantee that the Contractor will be paid any portion or the full amount of the Allowance. Expenditures of Owner's Allowance will be made through the issuance of a Change Order in accordance with the terms of the Agreement and the Procurement Ordinance and Procedures and supported with proper documentation supporting the change. FISCAL IMPACT: The source of funding is Water User Fees, Fund (412). The budget is being established as part of the capital project funding reallocation discussed in item 16.C.6. The project is expected to be completed in 2020. Annual operating costs for this replacement water main are expected to remain the same or decrease. Packet Pg. 764 11.K 07/14/2020 LEGAL CONSIDERATIONS: This item is approved as to form and legality and requires majority vote for Board approval. -SRT GROWTH MANAGEMENT IMPACT: This project meets current Growth Management Plan standards to ensure the adequacy and availability of viable public facilities. RECOMMENDATION: To award ITB # 20-7752, "Hickory Road Water Main Improvements" (Project Number 70129), and the attached Agreement No. 20-7752, to Haskins, Inc., in the amount of $1,377,246.50, and authorize the Chairman to sign the attached Agreement. Prepared By: Benjamin N. Bullert, P.E., Principal Project Manager, Public Utilities Engineering and Project Management Division ATTACHMENTS 1. Attachment No 1 - 20-7752 Bid Tabulation (PDF) 2. Attachment No 2 - 20-7752 Bid Analysis (PDF) 3. Attachment No 3 - 20-7752 Bid Recommendation Ltr 06-17-2020 (PDF) 4. Attachment No 4 - 20-7752 NORA final (PDF) 5. [Linked] Attachment No 5 - 20-7752 Haskins_SignedwBonds (PDF) 6. Attachment No 6 - 20-7752 Haskins_ Insurance 7-1-20 (PDF) 7. Attachment No 7 - 20-7752 PowerPoint (PDF) Packet Pg. 765 11.K 07/14/2020 COLLIER COUNTY Board of County Commissioners Item Number: 11.K Doe ID: 12842 Item Summary: Recommendation to award Invitation to Bid ("ITB") No. 20-7752, "Hickory Road Water Main Improvements" (Project Number 70129), to Haskins, Inc., in the amount of $1,377,246.50, and authorize the Chairman to sign the attached agreement. (Tom Chmelik, Public Utilities Engineering and Project Management) Meeting Date: 07/14/2020 Prepared by: Title: — Public Utilities Planning and Project Management Name: Benjamin Bullert 07/02/2020 4:37 PM Submitted by: Title: Division Director - Public Utilities Eng — Public Utilities Planning and Project Management Name: Tom Chmelik 07/02/2020 4:37 PM Approved By: Review: Public Utilities Planning and Project Management Tom Chmelik Public Utilities Operations Support Tara Castillo Additional Reviewer Procurement Services Opal Vann Level 1 Purchasing Gatekeeper Procurement Services Sue Zimmerman Additional Reviewer Board of County Commissioners Jim Flanagan Additional Reviewer Wastewater Beth Johnssen Additional Reviewer Public Utilities Operations Support AmiaMarie Curry Additional Reviewer Public Utilities Department Drew Cody Level 1 Division Reviewer Procurement Services Sandra Herrera Additional Reviewer Public Utilities Department George Yilmaz Level 2 Division Administrator Review County Attorney's Office Scott Teach Level 2 Attorney Review Office of Management and Budget Debra Windsor Level 3 OMB Gatekeeper Review Budget and Management Office Ed Finn Additional Reviewer Office of Management and Budget Laura Zautcke Additional Reviewer County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review County Manager's Office Nick Casalanguida Level 4 County Manager Review Additional Reviewer Completed Completed 07/02/2020 4:39 PM Completed 07/02/2020 4:39 PM Completed 07/02/2020 4:44 PM Completed 07/02/2020 4:55 PM Completed 07/02/2020 5:10 PM Completed 07/02/2020 5:14 PM Completed 07/02/2020 5:53 PM Completed 07/06/2020 9:17 AM Completed 07/07/2020 3:59 PM Completed 07/08/2020 9:06 AM Completed 07/08/2020 9:27 AM Completed 07/08/2020 10:09 AM Completed 07/08/2020 10:44 AM Completed 07/08/2020 1:16 PM Completed 07/08/2020 1:49 PM Packet Pg. 766 07/14/2020 Board of County Commissioners MaryJo Brock Meeting Pending 07/14/2020 9:00 AM Packet Pg. 767 11.K.a Project #: 20-7752 Project Title: HICKORY ROAD WATER MAIN IMPROVEMENTS Bid Due Date: May 1, 2020 @ 3:00 pm BID TABULATION BIDDER: Item Item No. Description SECTION 1: GENERAL ITEM NO. DESCRIPTION 1 Mobilization / Demobilization 2 Maintenance of Traffic 3 Survey Layout & Record Drawings 4 Pre -Construction & Post -Construction Videos Bid Opened By: Sue Zimmerman Witnessed By: Jim Flanagan Procurement Strategist: Sue Zimmerman Notices Sent: 28,698 Project Manager: Benjamin Bullert Packages Viewed: 126 Bid Responses: 15 Cougar Contracting, LLC Haskins Inc. Thompkins Contracting Inc. PWC Joint Venture LLC Douglas N. Higgins, Inc. GT General Contractors LLC Unit Total Unit Total Unit Total Unit Total Unit Total Unit Total Unit Quantity Cost Cost Cost Cost Cost Cost Cost Cost Cost Cost Cost Cost EST R.P. Utility & Excavation Corp. Andrew Sitework LLC Mitchell & Stark Construction Co. American Pipeline Construction ENGINEERS ESTIMATE Inc. Metro Equipment Service Inc. Intercounty Engineering Inc. Quality Enterprises USA, Inc. Strickler Bros. Underground, Inc. LLC Coastal Concrete Products, LLC Cost I Cost I Cost I Cost I Cost I Cost I Cot I Cost I Cost I Cost I Cost I Cost I Cot I Cost I Cot I Cost I Cost I Cost Unit Total Unit Total Unit Total Unit Total Unit Total Unit Total Unit Total Unit Total Unit Total unit I otal Cost Cost QUANT. UNIT UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE 1 LS $ 99,587.93 $ 99,587.93 $ 40,000.00 $ 40,000.00 $ 109,677.23 $ 109,677.23 $ 50,000.00 $ 50,000.00 $ 120,000.00 $ 120,000.00 $ 120,000.00 $ 120,000.00 $ 149,704.26 $ 149,704.26 $ 77,989.00 $ 77,989.00 $ 88,000.00 $ 88,000.00 $ 140,000.00 $ 140,000.00 $ 163,100.00 $ 163,100.00 $ 330,000.00 $ 330,000.00 $ 90,000.00 $ 90,000.00 $ 350,000.00 $ 350,000.00 $ 118,500.00 $ 118,500.00 $ 100,000.00 $ 100,000.00 1 LS $ 53,078.03 $ 53,078.03 $ 24,000.00 $ 24,000.00 $ 73,093.86 $ 73,093.86 $ 15,000.00 $ 15,000.00 $ 60,000.00 $ 60,000.00 $ 20,000.00 $ 20,000.00 $ 224,000.00 $ 224,000.00 $139,937.00 $ 139,937.00 $ 32,000.00 $ 32,000.00 $ 68,000.00 $ 68,000.00 $ 11,785.00 $ 11,785.00 $ 74,215.00 $ 74,215.00 $ 10,000.00 $ 10,000.00 $ 20,000.00 $ 20,000.00 $ 65,000.00 $ 65,000.00 $ 50,000.00 $ 50,000.00 1 LS $ 13,328.50 $ 13,328.50 $ 35,000.00 $ 35,000.00 $ 27,498.08 $ 27,498.08 $ 15,000.00 $ 15,000.00 $ 15,000.00 $ 15,000.00 $ 10,000.00 $ 10,000.00 $ 50,000.00 $ 50,000.00 $108,593.00 $ 108,593.00 $ 36,700.00 $ 36,700.00 $ 15,000.00 $ 15,000.00 $ 19,642.00 $ 19,642.00 $ 20,340.00 $ 20,340.00 $ 12,000.00 $ 12,000.00 $ 15,000.00 $ 15,000.00 $ 16,900.00 $ 16,900.00 $ 15,000.00 $ 15,000.00 1 LS $ 1,575.00 $ 1,575.00 $ 3,300.00 $ 3,300.00 $ 4,122.43 $ 4,122.43 $ 2,600.00 $ 2,600.00 $ 8,000.00 $ 8,000.00 $ 5,000.00 $ 5,000.00 $ 5,000.00 $ 5,000.00 $ 3,445.00 $ 3,445.00 $ 2,350.00 $ 2,350.00 $ 2,000.00 $ 2,000.00 $ 4,490.00 $ 4,490.00 $ 600.00 $ 600.00 $ 3,000.00 $ 3,000.00 $ 2,000.00 $ 2,000.00 $ 6,500.00 $ 6,500.00 $ 5,000.00 $ 5,000.00 SECTION 1 SUBTOTAL: $ 167,569.46 $ 102,300.00 $ 214,391.60 $ 82,600.00 $ 203,000.00 $ 155,000.00 $ 428,704.26 $ 329,964.00 $ 159,050.00 $ 225,000.00 $ 199,017.00 $ 425,155.00 $ 115,000.00 $ 387,000.00 $ 206,900.00 $ 170,000.00 SECTION 2: WATER SYSTEM ITEM NO. DESCRIPTION EST. QUANT, 5 Install PVC Water Main Pipelines Labor Only) a. 24" PVC DR18 Water Main 385 b. 20" PVC DR18 Water Main 4,660 c. 16" PVC DR18 Water Main 571 d. 8" PVC DR18 Water Main 183 6 Install Gate Valve and Box Labor Only) a. 30" Gate Valve 1 b. 24" Gate Valve 1 c. 20" Gate Valve 6 d. 16" Gate Valve 8 e. 8" Gate Valve 3 7 Directional Drill DR 11 (Vanderbilt Beach Dr. @ Station 4+58 to 12+51) (Labor Only) 1 8 Subaqueous Crossing (Carica Road Station 8+50) (Labor Only) 1 9 Install Air Release Valve 2 10 Install Fire Hydrant Assembly Labor Only) 11 11 Install Bacteriological Sample Point a. Temporary 4 b. Permanent 4 12 Connect to Existing Water Main a. 30" Water Main Connection 1 b. 16" Water Main Connection 5 c. 8" Water Main Connection 4 UNIT I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE I I UNIT PRICE I EXTENDED PRICE LF $ 113.47 $ 43,685.95 $ 58.00 $ 22,330.00 $ 62.70 $ 24,139.50 $ 135.00 $ 51,975.00 $ 157.00 $ 60,445.00 $ 100.00 $ 38,500.00 $ 79.00 $ 30,415.00 $ 53.00 $ 20,405.00 $ 110.20 $ 42,427.00 $ 110.00 $ 42,350.00 $ 22.00 $ 8,470.00 $ 150.00 $ 57,750.00 $ 130.00 $ 50,050.00 $ 176.00 $ 67,760.00 $ 85.00 $ 32,725.00 $ 150.00 $ 57,750.00 LF $ 47.07 $ 219,346.20 $ 50.00 $ 233,000.00 $ 40.09 $ 186,819.40 $ 65.00 $ 302,900.00 $ 68.00 $ 316,880.00 $ 80.00 $ 372,800.00 $ 43.00 $ 200,380.00 $ 75.50 $ 351,830.00 $ 64.19 $ 299,125.40 $ 160.00 $ 745,600.00 $ 69.00 $ 321,540.00 $ 85.00 $ 396,100.00 $ 130.00 $ 605,800.00 $ 99.00 $ 461,340.00 $ 78.00 $ 363,480.00 $ 90.00 $ 419,400.00 LF $ 48.89 $ 27,916.19 $ 40.00 $ 22,840.00 $ 54.52 $ 31,130.92 $ 85.00 $ 48,535.00 $ 95.00 $ 54,245.00 $ 80.00 $ 45,680.00 $ 42.00 $ 23,982.00 $ 46.00 $ 26,266.00 $ 74.89 $ 42,762.19 $ 100.00 $ 57,100.00 $ 22.00 $ 12,562.00 $ 110.00 $ 62,810.00 $ 80.00 $ 45,680.00 $ 97.00 $ 55,387.00 $ 72.00 $ 41,112.00 $ 85.00 $ 48,535.00 LF $ 31.90 $ 5,837.70 $ 32.00 $ 5,856.00 $ 68.05 $ 12,453.15 $ 60.00 $ 10,980.00 $ 65.00 $ 11,895.00 $ 50.00 $ 9,150.00 $ 31.00 $ 5,673.00 $ 35.00 $ 6,405.00 $ 44.56 $ 8,154.48 $ 50.00 $ 9,150.00 $ 22.00 $ 4,026.00 $ 146.00 $ 26,718.00 $ 40.00 $ 7,320.00 $ 95.00 $ 17,385.00 $ 38.00 $ 6,954.00 $ 70.00 $ 12,810.00 24,500.00 $ EA $ 3,151.93 $ 3,151.93 $ 14,500.00 $ 14,500.00 $ 1,845.57 $ 1,845.57 $ 4,000.00 $ 4,000.00 $ 8,500.00 $ 8,500.00 $ 5,000.00 $ 5,000.00 $ 4,000.00 $ 4,000.00 25,000.00 $ 25,000.00 $ 4,000.00 $ 4,000.00 $ 6,033.00 $ 6,033.00 $ 7,820.00 $ 7,820.00 $ 4,490.00 $ 4,490.00 $ 6,915.00 $ 6,915.00 $ 4,000.00 $ 4,000.00 $ 10,000.00 $ 10,000.00 $ 24,500.00 $ EA $ 2,171.94 $ 2,171.94 $ 8,100.00 $ 8,100.00 $ 1,845.57 $ 1,845.57 $ 2,200.00 $ 2,200.00 $ 6,300.00 $ 6,300.00 $ 4,000.00 $ 4,000.00 $ 3,000.00 $ 3,000.00 $ 3,070.00 $ 3,070.00 $ 4,970.00 $ 4,970.00 $ 3,000.00 $ 3,000.00 $ 4,490.00 $ 4,490.00 $ 5,819.00 $ 5,819.00 $ 3,500.00 $ 3,500.00 $ 10,000.00 $ 10,000.00 $ 17,500.00 $ 17,500.00 $ 15,000.00 $ 15,000.00 EA $ 2,422.72 $ 14,536.32 $ 5,500.00 $ 33,000.00 $ 1,845.57 $ 11,073.42 $ 1,000.00 $ 6,000.00 $ 2,700.00 $ 16,200.00 $ 3,700.00 $ 22,200.00 $ 2,500.00 $ 15,000.00 $ 2,630.00 $ 15,780.00 $ 3,700.00 $ 22,200.00 $ 2,000.00 $ 12,000.00 $ 4,490.00 $ 26,940.00 $ 3,250.00 $ 19,500.00 $ 3,000.00 $ 18,000.00 $ 7,000.00 $ 42,000.00 $ 14,500.00 $ 87,000.00 $ 10,000.00 $ 60,000.00 EA $ 1,790.19 $ 14,321.52 $ 3,300.00 $ 26,400.00 $ 1,845.57 $ 14,764.56 $ 1,200.00 $ 9,600.00 $ 2,000.00 $ 16,000.00 $ 2,000.00 $ 16,000.00 $ 2,174.00 $ 17,392.00 $ 2,155.00 $ 17,240.00 $ 3,040.00 $ 24,320.00 $ 600.00 $ 4,800.00 $ 4,490.00 $ 35,920.00 $ 3,007.00 $ 24,056.00 $ 2,500.00 $ 20,000.00 $ 5,000.00 $ 40,000.00 $ 12,500.00 $ 100,000.00 $ 8,500.00 $ 68,000.00 EA $ 375.40 $ 1,126.20 $ 1,950.00 $ 5,850.00 $ 1,444.22 $ 4,332.66 $ 630.00 $ 1,890.00 $ 1,100.00 $ 3,300.00 $ 1,200.00 $ 3,600.00 $ 1,850.00 $ 5,550.00 $ 675.00 $ 2,025.00 $ 2,000.00 $ 6,000.00 $ 500.00 $ 1,500.00 $ 4,490.00 $ 13,470.00 $ 1,906.00 $ 51718.00 $ 2,000.00 $ 6,000.00 $ 4,000.00 $ 12,000.00 $ 2,500.00 $ 7,500.00 $ 2,000.00 $ 6,000.00 LS $ 136,650.53 $ 136,650.53 $ 102,000.00 $ 102,000.00 $ 176,260.62 $ 176,260.62 $ 110,000.00 $ 110,000.00 $ 105,000.00 $ 105,000.00 $ 150,000.00 $ 150,000.00 $ 200,000.00 $ 200,000.00 $129,953.00 $ 129,953.00 $140,180.00 $ 140,180.00 $ 150,000.00 $ 150,000.00 $ 119,985.00 $ 119,985.00 $ 108,483.00 $ 108,483.00 $ 126,000.00 $ 126,000.00 $ 115,000.00 $ 115,000.00 $ 168,500.00 $ 168,500.00 $ 180,000.00 $ 180,000.00 LS $ 15,816.86 $ 15,816.86 $ 15,000.00 $ 15,000.00 $ 16,848.54 $ 16,848.54 $ 35,000.00 $ 35,000.00 $ 38,000.00 $ 38,000.00 $ 60,000.00 $ 60,000.00 $ 25,000.00 $ 25,000.00 $ 32,087.00 $ 32,087.00 $ 20,000.00 $ 20,000.00 $ 5,000.00 $ 5,000.00 $ 104,664.00 $ 104,664.00 $ 22,546.00 $ 22,546.00 $ 30,000.00 $ 30,000.00 $ 45,000.00 $ 45,000.00 $ 29,500.00 $ 29,500.00 $ 75,000.00 $ 75,000.00 EA $ 1,530.77 $ 3,061.54 $ 3,300.00 $ 6,600.00 $ 1,444.22 $ 2,888.44 $ 3,000.00 $ 6,000.00 $ 2,300.00 $ 4,600.00 $ 3,000.00 $ 6,000.00 $ 2,672.00 $ 5,344.00 $ 1,961.00 $ 3,922.00 $ 2,060.00 $ 4,120.00 $ 1,500.00 $ 3,000.00 $ 1,263.00 $ 2,526.00 $ 1,154.00 $ 2,308.00 $ 2,000.00 $ 4,000.00 $ 3,000.00 $ 6,000.00 $ 7,500.00 $ 15,000.00 $ 2,900.00 $ 5,800.00 EA $ 1,513.73 $ 16,651.03 $ 3,625.00 $ 39,875.00 $ 1,287.99 $ 14,167.89 $ 2,800.00 $ 30,800.00 $ 1,500.00 $ 16,500.00 $ 1,200.00 $ 13,200.00 $ 4,000.00 $ 44.000.00 $ 2,488.00 $ 27,368.00 $ 2,500.00 $ 27.500.00 $ 1,000.00 $ 11,000.00 $ 1,263.00 $ 13,893.00 $ 3,922.00 $ 43,142.00 $ 5,000.00 $ 55,000.00 $ 3,500.00 $ 38,500.00 $ 4,500.00 $ 49,500.00 $ 2,500.00 $ 27,500.00 $ 2,500.00 $ 10,000.00 $ 200.00 $ 800.00 EA $ 217.49 $ 869.96 $ 2,500.00 $ 10,000.00 $ 3,113.37 $ 12,453.48 $ 1,000.00 $ 4,000.00 $ 900.00 $ 3,600.00 $ 1,000.00 $ 4,000.00 SECTION 3: RESTORATION ITEM NO. DESCRIPTION EST. UNIT UNIT PRICE EXTENDED PRICE QUANT. 13 General Restoration 1 LS $ 219,965.58 $ 219,965.58 14 Abandon & Remove Existing Water Main a. Abandon & Remove 8" Water Main 33 LF $ 50.03 $ 1,650.99 b. Abandon & Remove 12" Water Main 4,626 LF $ 8.66 $ 40,061.16 15 Abandon & Grout Existing 12" Main 1,290 LF $ 8.20 $ 10,578.00 16 Driveway Restoration a. Concrete 761 SY $ 70.52 $ 53,665.72 b. Asphalt/Gravel 450 SY $ 59.69 $ 26,860.50 c. Brick 427 SY $ 159.36 $ 68,046.72 17 Sidewalk Restoration (FDOT 157 SY $ 73.97 $ 11,613.29 Right of Way) 18 Roadway Restoration a. Vanderbilt @ Station 4+50 94 SY $ 244.54 $ 22,986.76 b RaOnderbilt @Station 6+50 (FDOT 64 SY $ 252.82 $ 16,180.48 c. Hickory & Cassena 334 SY $ 41.64 $ 13,907.76 d. Hickory & Tupelo 333 SY $ 41.68 $ 13,879.44 e. Hickory & Carica 515 SY $ 42.59 $ 21,933.85 f. Carica & Goodlette 30 SY $ 154.95 $ 4,648.50 Goodlette (South bound) @ Station 9. 2+00 135 SY $ 121.32 $ 16,378.20 h Goodlette (North bound) @ Station 56 SY $ 127.13 $ 7,119.28 2+00 SECTION 3 SUBTOTAL: $ 549,476.23 SECTION 4: ALLOWANCE Owner's Allowance for Owner's Use as Directed: This Owner's Allowance will be used only at the Owner's direction to accomplish work due to unforeseen conditions and/or as directed by the Owner. Inclusion of the Owner's Allowance as 19 part of the Contract Price is not a guarantee that the Contractor T&M $100,000 $ 100,000.00 will be paid any portion or full amount of the Allowance. Expenditures of Owner's Allowance will be made through Change Order with proper documentation of Time and Materials supporting the change. SECTION 4: ALLOWANCE SUBTOTAL:1 $ 100,000.00 BID SUMMARY SECTION 1 GENERAL SUBTOTAL: $ 167,569.46 SECTION 2 WATER SYSTEM SUBTOTAL: $ 533,355.00 SECTION 3 RESTORATION SUBTOTAL: $ 549,476.23 SECTION 4 OWNER'S ALLOWANCE: $ 100,000.00 BID TOTAL: $ 1,350,400.69 REQUIREMENTS: Yes/No/N/A BID RESPONSE FORMS Bid Response Form (Form 1) Yes Contractors Key Personnel - Exh. N (Form 2) Yes Material Manufacturers (Form 3) Yes List of Major Subcontractors (Form 4) Yes Statement of Experience of Bidder (Form 5) Yes Trench Safety Act Acknowledgement (Form 6) Yes Bid Bond (Form 7) Yes Insurance and Bonding Requirements (Form 8) Yes Conflict of Interest Affidavit (Form 9) Yes Vendor Declaration Statement (Form 10) Yes Immigration Affidavit Certification (Form 11) Yes Bidders Checklist (Form 12) Yes Addendums (3) Yes Copies of Information Required in Item 9 of Bidder's Checklist Business Tax Receipt (Collier County Business Only) N/A Company's E-Verify Profile or MOU Yes Certificate of Authority to Conduct Business in State of Florida (Sunbiz.org) Yes State of Florida Professional License(s) - valid and current 2018 General Contractor CONTRACTOR'S QUALIFICATIONS(per Specs) Installing large diameter water mains w/in past 5 years TBD Extensive experience and equipment to complete directional drill under US41 - performed at least 2 directional drills within a State Right-of-way Min past 5 TBD Experience installing pipelines in a neighborhood Min past 5 years TBD Place of Business; Ft. Myers County i i I i Lee UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 20.00 $ 660.00 $ 16.75 $ 77,485.50 $ 9.00 $ 11,610.00 $ 70.00 $ 53,270.00 $ 108.00 $ 48,600.00 $ 160.00 $ 68,320.00 $ 95.00 $ 14,915.00 $ 185.00 $ 17,390.00 $ 390.00 $ 24,960.00 $ 95.00 $ 31, 730.00 $ 95.00 $ 31,635.00 $ 90.00 $ 46,350.00 $ 540.00 $ 16,200.00 $ 170.00 $ 22,950.00 $ 270.00 $ 15,120.00 $ 561,195.50 $100,000 $ 100,000.00 $ 100,000.00 $ 102,300.00 $ 613,751.00 $ 561,195.50 $ 100,000.00 $ 1,377,246.50 UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ SECTION 4: ALLOWANCE Owner's Allowance for Owner's Use as Directed: This Owner's Allowance will be used only at the Owner's direction to accomplish work due to unforeseen conditions and/or as directed by the Owner. Inclusion of the Owner's Allowance as 19 part of the Contract Price is not a guarantee that the Contractor T&M $100,000 $ 100,000.00 will be paid any portion or full amount of the Allowance. Expenditures of Owner's Allowance will be made through Change Order with proper documentation of Time and Materials supporting the change. SECTION 4: ALLOWANCE SUBTOTAL:1 $ 100,000.00 BID SUMMARY SECTION 1 GENERAL SUBTOTAL: $ 167,569.46 SECTION 2 WATER SYSTEM SUBTOTAL: $ 533,355.00 SECTION 3 RESTORATION SUBTOTAL: $ 549,476.23 SECTION 4 OWNER'S ALLOWANCE: $ 100,000.00 BID TOTAL: $ 1,350,400.69 REQUIREMENTS: Yes/No/N/A BID RESPONSE FORMS Bid Response Form (Form 1) Yes Contractors Key Personnel - Exh. N (Form 2) Yes Material Manufacturers (Form 3) Yes List of Major Subcontractors (Form 4) Yes Statement of Experience of Bidder (Form 5) Yes Trench Safety Act Acknowledgement (Form 6) Yes Bid Bond (Form 7) Yes Insurance and Bonding Requirements (Form 8) Yes Conflict of Interest Affidavit (Form 9) Yes Vendor Declaration Statement (Form 10) Yes Immigration Affidavit Certification (Form 11) Yes Bidders Checklist (Form 12) Yes Addendums (3) Yes Copies of Information Required in Item 9 of Bidder's Checklist Business Tax Receipt (Collier County Business Only) N/A Company's E-Verify Profile or MOU Yes Certificate of Authority to Conduct Business in State of Florida (Sunbiz.org) Yes State of Florida Professional License(s) - valid and current 2018 General Contractor CONTRACTOR'S QUALIFICATIONS(per Specs) Installing large diameter water mains w/in past 5 years TBD Extensive experience and equipment to complete directional drill under US41 - performed at least 2 directional drills within a State Right-of-way Min past 5 TBD Experience installing pipelines in a neighborhood Min past 5 years TBD Place of Business; Ft. Myers County i i I i Lee UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 20.00 $ 660.00 $ 16.75 $ 77,485.50 $ 9.00 $ 11,610.00 $ 70.00 $ 53,270.00 $ 108.00 $ 48,600.00 $ 160.00 $ 68,320.00 $ 95.00 $ 14,915.00 $ 185.00 $ 17,390.00 $ 390.00 $ 24,960.00 $ 95.00 $ 31, 730.00 $ 95.00 $ 31,635.00 $ 90.00 $ 46,350.00 $ 540.00 $ 16,200.00 $ 170.00 $ 22,950.00 $ 270.00 $ 15,120.00 $ 561,195.50 $100,000 $ 100,000.00 $ 100,000.00 $ 102,300.00 $ 613,751.00 $ 561,195.50 $ 100,000.00 $ 1,377,246.50 UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ BID SUMMARY SECTION 1 GENERAL SUBTOTAL: $ 167,569.46 SECTION 2 WATER SYSTEM SUBTOTAL: $ 533,355.00 SECTION 3 RESTORATION SUBTOTAL: $ 549,476.23 SECTION 4 OWNER'S ALLOWANCE: $ 100,000.00 BID TOTAL: $ 1,350,400.69 REQUIREMENTS: Yes/No/N/A BID RESPONSE FORMS Bid Response Form (Form 1) Yes Contractors Key Personnel - Exh. N (Form 2) Yes Material Manufacturers (Form 3) Yes List of Major Subcontractors (Form 4) Yes Statement of Experience of Bidder (Form 5) Yes Trench Safety Act Acknowledgement (Form 6) Yes Bid Bond (Form 7) Yes Insurance and Bonding Requirements (Form 8) Yes Conflict of Interest Affidavit (Form 9) Yes Vendor Declaration Statement (Form 10) Yes Immigration Affidavit Certification (Form 11) Yes Bidders Checklist (Form 12) Yes Addendums (3) Yes Copies of Information Required in Item 9 of Bidder's Checklist Business Tax Receipt (Collier County Business Only) N/A Company's E-Verify Profile or MOU Yes Certificate of Authority to Conduct Business in State of Florida (Sunbiz.org) Yes State of Florida Professional License(s) - valid and current 2018 General Contractor CONTRACTOR'S QUALIFICATIONS(per Specs) Installing large diameter water mains w/in past 5 years TBD Extensive experience and equipment to complete directional drill under US41 - performed at least 2 directional drills within a State Right-of-way Min past 5 TBD Experience installing pipelines in a neighborhood Min past 5 years TBD Place of Business; Ft. Myers County i i I i Lee UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 20.00 $ 660.00 $ 16.75 $ 77,485.50 $ 9.00 $ 11,610.00 $ 70.00 $ 53,270.00 $ 108.00 $ 48,600.00 $ 160.00 $ 68,320.00 $ 95.00 $ 14,915.00 $ 185.00 $ 17,390.00 $ 390.00 $ 24,960.00 $ 95.00 $ 31, 730.00 $ 95.00 $ 31,635.00 $ 90.00 $ 46,350.00 $ 540.00 $ 16,200.00 $ 170.00 $ 22,950.00 $ 270.00 $ 15,120.00 $ 561,195.50 $100,000 $ 100,000.00 $ 100,000.00 $ 102,300.00 $ 613,751.00 $ 561,195.50 $ 100,000.00 $ 1,377,246.50 UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ REQUIREMENTS: Yes/No/N/A BID RESPONSE FORMS Bid Response Form (Form 1) Yes Contractors Key Personnel - Exh. N (Form 2) Yes Material Manufacturers (Form 3) Yes List of Major Subcontractors (Form 4) Yes Statement of Experience of Bidder (Form 5) Yes Trench Safety Act Acknowledgement (Form 6) Yes Bid Bond (Form 7) Yes Insurance and Bonding Requirements (Form 8) Yes Conflict of Interest Affidavit (Form 9) Yes Vendor Declaration Statement (Form 10) Yes Immigration Affidavit Certification (Form 11) Yes Bidders Checklist (Form 12) Yes Addendums (3) Yes Copies of Information Required in Item 9 of Bidder's Checklist Business Tax Receipt (Collier County Business Only) N/A Company's E-Verify Profile or MOU Yes Certificate of Authority to Conduct Business in State of Florida (Sunbiz.org) Yes State of Florida Professional License(s) - valid and current 2018 General Contractor CONTRACTOR'S QUALIFICATIONS(per Specs) Installing large diameter water mains w/in past 5 years TBD Extensive experience and equipment to complete directional drill under US41 - performed at least 2 directional drills within a State Right-of-way Min past 5 TBD Experience installing pipelines in a neighborhood Min past 5 years TBD Place of Business; Ft. Myers County i i I i Lee UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 20.00 $ 660.00 $ 16.75 $ 77,485.50 $ 9.00 $ 11,610.00 $ 70.00 $ 53,270.00 $ 108.00 $ 48,600.00 $ 160.00 $ 68,320.00 $ 95.00 $ 14,915.00 $ 185.00 $ 17,390.00 $ 390.00 $ 24,960.00 $ 95.00 $ 31, 730.00 $ 95.00 $ 31,635.00 $ 90.00 $ 46,350.00 $ 540.00 $ 16,200.00 $ 170.00 $ 22,950.00 $ 270.00 $ 15,120.00 $ 561,195.50 $100,000 $ 100,000.00 $ 100,000.00 $ 102,300.00 $ 613,751.00 $ 561,195.50 $ 100,000.00 $ 1,377,246.50 UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 20.00 $ 660.00 $ 16.75 $ 77,485.50 $ 9.00 $ 11,610.00 $ 70.00 $ 53,270.00 $ 108.00 $ 48,600.00 $ 160.00 $ 68,320.00 $ 95.00 $ 14,915.00 $ 185.00 $ 17,390.00 $ 390.00 $ 24,960.00 $ 95.00 $ 31, 730.00 $ 95.00 $ 31,635.00 $ 90.00 $ 46,350.00 $ 540.00 $ 16,200.00 $ 170.00 $ 22,950.00 $ 270.00 $ 15,120.00 $ 561,195.50 $100,000 $ 100,000.00 $ 100,000.00 $ 102,300.00 $ 613,751.00 $ 561,195.50 $ 100,000.00 $ 1,377,246.50 UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 102,300.00 $ 613,751.00 $ 561,195.50 $ 100,000.00 $ 1,377,246.50 UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 22,723.83 $ 22,723.83 $ 74.65 $ 21463.45 $ 30.64 $ 141, 740.64 $ 33.07 $ 42,660.30 $ 85.02 $ 64,700.22 $ 61.01 $ 27,454.50 $ 19.24 $ 8,215.48 $ 223.61 $ 35,106.77 $ 143.83 $ 13,520.02 $ 183.55 $ 11, 747.20 $ 112.33 $ 37,518.22 $ 112.46 $ 37,449.18 $ 97.95 $ 50,444.25 $ 170.17 $ 5,105.10 $ 129.74 $ 17,514.90 $ 181.78 $ 10,179.68 $ 528,543.74 $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 214,391.60 $ 552,427.41 $ 528,543.74 $ 100,000.00 $ 1,395,362.75 UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 120,000.00 $ 120,000.00 $ 28.00 $ 924.00 $ 10.00 $ 46,260.00 $ 25.00 $ 32,250.00 $ 85.00 $ 64,685.00 $ 85.00 $ 38,250.00 $ 80.00 $ 34,160.00 $ 105.00 $ 16,485.00 $ 85.00 $ 7,990.00 $ 85.00 $ 5,440.00 $ 85.00 $ 28,390.00 $ 85.00 $ 28,305.00 $ 85.00 $ 43,775.00 $ 150.00 $ 4,500.00 $ 85.00 $ 11,475.00 $ 85.00 $ 4,760.00 $ 487,649.00 $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 82,600.00 $ 734,880.00 $ 487,649.00 $ 100,000.00 $ 1,405,129.00 UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 63, 000.00 $ 63, 000.00 $ 15.00 $ 495.00 $ 11.00 $ 50,886.00 $ 6.00 $ 7,740.00 $ 70.00 $ 53,270.00 $ 65.00 $ 29,250.00 $ 87.00 $ 37,149.00 $ 80.00 $ 12,560.00 $ 140.00 $ 13,160.00 $ 140.00 $ 8,960.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25, 750.00 $ 80.00 $ 2,400.00 $ 140.00 $ 18, 900.00 $ 140.00 $ 7,840.00 $ 364,710.00 $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 203,000.00 $ 759,265.00 $ 364,710.00 $ 100,000.00 $ 1,426,975.00 UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 14.00 $ 462.00 $ 15.00 $ 69,390.00 $ 20.00 $ 25,800.00 $ 45.00 $ 34,245.00 $ 45.00 $ 20,250.00 $ 45.00 $ 19,215.00 $ 50.00 $ 7,850.00 $ 50.00 $ 4,700.00 $ 50.00 $ 3,200.00 $ 50.00 $ 16,700.00 $ 50.00 $ 16,650.00 $ 50.00 $ 25,750.00 $ 50.00 $ 1,500.00 $ 50.00 $ 61750.00 $ 50.00 $ 2,800.00 $ 335,262.00 $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 155,000.00 $ 856,130.00 $ 335,262.00 $ 100,000.00 $ 1,446,392.00 Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes No Yes Yes Yes Yes Yes Yes Yes Yes Lee N/A N/A Collier Coral Springs Yes Yes Yes Yes No Yes Yes Yes Yes Yes 2008 Underground 2008 Underground 2016 General Contractor 1998 General Contractor 2002 General Contractor Registered Ind Underground TBD TBD TBD Yes TBD TBD TBD TBD Sub & Higgins Yes TBD TBD TBD TBD Yes TBD Bonita Springs Lehigh Acres Fort Myers Naples Coral Springs Lee Lee Lee Collier Broward UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 100, 000.00 $ 100,000.00 $127,144.00 $ 127,144.00 $ 11.00 $ 363.00 $ 28.00 $ 924.00 $ 11.00 $ 50,886.00 $ 8.50 $ 39,321.00 $ 18.00 $ 23,220.00 $ 12.60 $ 16,254.00 $ 44.10 $ 33,560.10 $ 80.00 $ 60,880.00 $ 26.80 $ 12,060.00 $ 58.00 $ 26,100.00 $ 44.98 $ 19,206.46 $ 56.00 $ 23,912.00 $ 38.70 $ 6,075.90 $ 84.00 $ 13,188.00 $ 35.32 $ 3,320.08 $ 76.00 $ 7,144.00 $ 35.32 $ 2,260.48 $ 76.00 $ 4,864.00 $ 35.32 $ 11,796.88 $ 71.00 $ 23,714.00 $ 35.32 $ 11,761.56 $ 71.00 $ 23,643.00 $ 35.32 $ 18,189.80 $ 71.00 $ 36, 565.00 $ 35.32 $ 1,059.60 $ 82.30 $ 2,469.00 $ 35.32 $ 4,768.20 $ 73.00 $ 9,855.00 $ 35.32 $ 1,977.92 $ 78.00 $ 4,368.00 $ 300,505.98 $ 420,345.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $ 428,704.26 $ 329,964.00 $ 670,132.00 $ 724,351.00 $ 300,505.98 $ 420,345.00 $ 100,000.00 $ 100,000.00 $ 15499,342.24 $ 1,574,660.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A Lee Yes Yes Yes Yes 2011 Underground 2008 Underground Yes TBD TBD TBD TBD TBD Hialeah Fort Myers Miami -Dade Lee UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $136, 000.00 $ 136, 000.00 $ 75.00 $ 2,475.00 $ 15.00 $ 69, 390.00 $ 15.00 $ 19, 350.00 $ 67.05 $ 51, 025.05 $ 75.00 $ 33,750.00 $ 79.00 $ 33,733.00 $ 40.00 $ 6,280.00 LL $ 500.00 $ 47,000.00 $ 500.00 $ 32,000.00 $ 75.00 $ 25, 050.00 $ 85.00 $ 28, 305.00 $ 85.00 $ 43,775.00 $ 300.00 $ 9,000.00 $ 300.00 $ 40,500.00 $ 500.00 $ 28,000.00 $ 605,633.05 $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 159,050.00 $ 735,999.07 $ 605,633.05 $ 100,000.00 $ 1,600,682.12 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No No No TBD TBD TBD Vaples Collier UNIT PRICE EXTENDED PRICE $ 15, 000.00 $ 15, 000.00 $ 20.00 $ 660.00 $ 4.00 $ 18, 504.00 $ 7.00 $ 9,030.00 $ 98.00 $ 74,578.00 $ 40.00 $ 18,000.00 $ 90.00 $ 38,430.00 $ 70.00 $ 10,990.00 $ 60.00 $ 5,640.00 $ 60.00 $ 3,840.00 $ 40.00 $ 13,360.00 $ 40.00 $ 13,320.00 $ 40.00 $ 20,600.00 $ 40.00 $ 1,200.00 $ 60.00 $ 8,100.00 $ 60.00 $ 3,360.00 $ 254,612.00 $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 225,000.00 $ 11107,100.00 $ 254,612.00 $ 100,000.00 $ 1,686,712.00 Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A No No No No Yes No Yes No No No No No Yes Miami -Dade Yes Yes 1991 Underground 2004 General Contractor TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE UNIT PRICE EXTENDED PRICE $ 103,261.00 $ 103,261.00 $ 5,935.00 $ 5,935.00 $ 77.00 $ 2,541.00 $ 75.00 $ 2,475.00 $ 63.00 $ 291,438.00 $ 14.00 $ 64,764.00 $ 77.00 $ 99,330.00 $ 11.50 $ 14,835.00 $ 119.00 $ 90,559.00 $ 101.00 $ 76,861.00 $ 34.00 $ 15,300.00 $ 77.00 $ 34,650.00 $ 34.00 $ 14,518.00 $ 126.00 $ 53,802.00 $ 34.00 $ 5,338.00 $ 101.00 $ 15,857.00 $ 60.00 $ 5,640.00 $ 146.00 $ 13,724.00 $ 60.00 $ 3,840.00 $ 144.00 $ 9,216.00 $ 60.00 $ 20,040.00 $ 86.00 $ 28,724.00 $ 60.00 $ 19,980.00 $ 85.00 $ 28,305.00 $ 60.00 $ 30,900.00 $ 78.00 $ 40,170.00 $ 60.00 $ 1,800.00 $ 350.00 $ 10,500.00 $ 60.00 $ 8,100.00 $ 142.00 $ 19,170.00 $ 60.00 $ 3,360.00 $ 223.00 $ 12,488.00 $ 715,945.00 $ 431,476.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $ 199,017.00 $ 425,155.00 $ 727,980.00 $ 846,212.00 $ 715,945.00 $ 431,476.00 $ 100,000.00 $ 100,000.00 $ 1,742,942.00 $ 1,802,843.00 Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes N/A No Yes Yes Yes Yes 2019 Underground 2001 Underground 2019 General Contractor TBD TBD TBD TBD TBD TBD Pompano Beach Naples Broward Collier UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 200,000.00 $ 200,000.00 $ 10.00 $ 330.00 $ 20.00 $ 92,520.00 $ 20.00 $ 25,800.00 $ 90.00 $ 68,490.00 $ 35.00 $ 15,750.00 $ 200.00 $ 85,400.00 $ 70.00 $ 10,990.00 $ 35.00 $ 3,290.00 $ 240.00 $ 15,360.00 $ 35.00 $ 11, 690.00 $ 35.00 $ 11, 655.00 $ 35.00 $ 18, 025.00 $ 35.00 $ 17050.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 579,450.00 $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 115,000.00 $ 1,074,950.00 $ 579,450.00 $ 100,000.00 $ 1,869,400.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 1990 Underground TBD TBD TBD Fort Myers Lee UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 10.00 $ 330.00 $ 8.00 $ 37,008.00 $ 6.00 $ 7,740.00 $ 55.00 $ 41, 855.00 $ 50.00 $ 22,500.00 $ 60.00 $ 25,620.00 $ 50.00 $ 7,850.00 LL $ 100.00 $ 9,400.00 $ 100.00 $ 6,400.00 $ 100.00 $ 33,400.00 $ 100.00 $ 33,300.00 $ 100.00 $ 51,500.00 $ 100.00 $ 3,000.00 $ 100.00 $ 13,500.00 $ 100.00 $ 5,600.00 $ 399,003.00 $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $ 100,000.00 $ 387,000.00 $ 1,034,772.00 $ 399,003.00 $ 100,000.00 $ 1,920,775.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Miami -Dade Yes Yes 2016 Underground TBD TBD TBD Miami Miami -Dade UNIT PRICE EXTENDED PRICE $ 87,000.00 $ 87,000.00 $ 20.00 $ 660.00 $ 22.00 $ 101, 772.00 $ 30.00 $ 38,700.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 95.00 $ 40,565.00 $ 75.00 $ 11,775.00 $ 165.00 $ 15,510.00 $ 165.00 $ 10,560.00 $ 165.00 $ 55,110.00 $ 165.00 $ 54,945.00 $ 165.00 $ 84,975.00 $ 165.00 $ 4,950.00 $ 165.00 $ 22,275.00 $ 165.00 $ 9,240.00 $ 624,362.00 UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ UNIT PRICE EXTENDED PRICE $ 100,000.00 $ 100,000.00 $ 25.00 $ 825.00 $ 12.00 $ 55,512.00 $ 15.00 $ 19,350.00 $ 75.00 $ 57,075.00 $ 65.00 $ 29,250.00 $ 75.00 $ 32,025.00 $ 100.00 $ 15,700.00 $ 300.00 $ 28,200.00 $ 300.00 $ 19,200.00 $ 60.00 $ 20,040.00 $ 60.00 $ 19,980.00 $ 60.00 $ 30,900.00 $ 150.00 $ 4,500.00 $ 200.00 $ 27,000.00 $ 200.00 $ 11,200.00 $ 470,757.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $100,000 $ 100,000.00 $100,000 $ 100,000.00 $ 100,000.00 $ 100,000.00 $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ $ 206,900.00 $ 1,039,271.00 $ 624,362.00 $ 100,000.00 $ 1,970.533.00 Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ Yes/No/N/A Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Yes Lee Yes Yes 2011 General Contractor TBD TBD TBD Fort Myers Lee $ 170,000.00 $ 11126,295.00 $ 470,757.00 $ 100,000.00 $ 1,867,052.00 a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ a� E a� > 0 L :a. E _ as a 0 0 1 'x N v cw N 0 ca H 00 N LO ti ti 0 N 0 z E 2 a E c� w Q $ 600.00 $ 21400.00 $ 1,263.00 $ 5,052.00 $ 11283.00 $ 5,132.00 $ 120.00 $ 480.00 $ 1,916.00 $ 7,664.00 $ 787.00 $ 3,148.00 $ 400.00 $ 1,600.00 $ 400.00 $ 1,600.00 Packet Pg. 768 $2,500,000.00 $2,300,000.00 $ 2,100, 000.00 $1, 900, 000.00 $1, 700, 000.00 $1, 500, 000.00 $1, 300,000.00 $1,100, 000.00 $900,000.00 $700,000.00 $500,000.00 Results for Bid 20-7752 Hickory Road Water Main Improvements K-6 �C°���a 5 °��` �a5�� a�C°��t ��+Ga a�e��'\ �5�a� J�Q�e� a���� �aFc�et ` eta` Q.Qe\.� \Lo OP G C KEY: Dashed Green - AVERAGE BID Dashed black- +/- 1 std dev of avg bid C E O L Q. E c L d O O O x N Go N L .y c a m N LO ti ti O N N O Z c w E t c� Q C d t v a Packet Pg. 769 E N G I N E E R I N G June 17, 2020 Via Email Only: Sue.Zimmerman(n,colliercountyfl.2ov Ms. Sue Zimmerman, CPM Procurement Manager Collier County Procurement Services Division 3295 Tamiami Trail East Naples, FL 34112-5361 RE: Design Entity's Letter of Review & Acknowledgement Collier County Solicitation No.: 20-7752 Project: Hickory Road Water Main Improvements Dear Sue: The bid opening for the above -referenced project took place on May 5, 2020. Collier County provided the results of the bid opening to Johnson Engineering and we performed an evaluation of the results and our recommendation is contained herein. The table below lists the 15 responsive bidders and their bid amounts submitted from lowest to highest: BIDDER BID AMOUNT Cougar Contracting, LLC $1,350,400.69 Haskins, Inc. $1,377,246.50 Thompkins Contracting, Inc. $1,395,362.75 PWC Joint Venture LLC $1,405,129.00 Douglas N. Higgins, Inc. $1,426,975.00 GT General Contractors LLC $1,446,392.00 R.P. Utility & Excavation Corp. $1,499,342.24 Andrew Sitework LLC $1,574,660.00 Mitchell & Stark Construction Co., Inc. $1,600,682.12 Metro Equipment Service, Inc. $1,686,712.00 as a 0 0 Y 'x N le 00 N 2122 Johnson Street . Post Office Box 1550 . Fort Myers, Florida 33902-1550 (239) 334-0046 . Fax (239) 334-3661 Packet Pg. 770 11.K.c Ms. Sue Zimmerman, CPM Re: Design Entity's Letter of Review & Acknowledgement Collier County Solicitation No.: 20-7752 Project: Hickory Road Water Main Improvements June 17, 2020 Page 2 BIDDER (Continued) BID AMOUNT Intercounty Engineering, Inc. $1,742,942.00 Quality Enterprises USA, Inc. $1,802,843.00 Strickler Bros. Underground, Inc. $1,869,400.00 American Pipeline Construction LLC $1,920,775.00 Coastal Concrete Products, LLC $1,970,533.00 Following the bid opening, Collier County prepared the enclosed Bid Tabulation Analysis, which includes an analysis for mathematical errors. Collier County did find and correct some mathematical errors but these errors did not change the overall bid rankings. For comparison purposes, Johnson Engineering, Inc. provided Collier County with an Opinion of Probable Construction Cost in the amount of $1,867,052.00. The results of the Bid Tabulation Analysis show Cougar Contracting, LLC as the lowest bidder. Research of Cougar Contracting, LLC The low bid submitted by Cougar Contracting, LLC of $1,350,400.69 was $516,651.31 lower (28%) than the Engineer's Opinion of Probable Construction Cost. Cougar Contracting, LLC did acknowledge Bid Addendums #1, #2, and #3, and all the required forms. The project specifications require the Design Entity to contact the references provided by the Bidder, and verify that the Contractor, or their Sub -Contractor (if identified in the Bid), meets the requirements identified in Supplemental Specifications #3 Contractor's Qualifications. Cougar Contracting, LLC did not identify any sub- contractors in the Bid. Johnson Engineering placed three phone calls (3) and one (1) email with each reference contact provided in the Bid submitted by Cougar Contracting, LLC. Two (2) of the six (6) references provided in the Bid submitted by Cougar Contracting, LLC were responsive to our communications. The responses from those references are provided in the attachments section of this letter. The references that were responsive did confirm the referenced projects and contract amounts, and generally had good comments. However, they could not confirm that Cougar Contracting, LLC meets the required contractor's qualifications identified in the Project Specifications. Based upon this research, the low bidder, Cougar Contracting, LLC, appears not to be a responsive and responsible bidder due to failing to provide references or documentation that verify they meet the required contractor's qualifications identified in the Project Specifications. Packet Pg. 771 11.K.c Ms. Sue Zimmerman, CPM Re: Design Entity's Letter of Review & Acknowledgement Collier County Solicitation No.: 20-7752 Project: Hickory Road Water Main Improvements June 17, 2020 Page 3 Research of Haskins, Inc. The second lowest bid submitted by Haskin, Inc. of $1,377,246.50 was $489,805.50 lower (26%) than the Engineer's Opinion of Probable Construction Cost. Haskins, Inc. did acknowledge Bid Addendums #1, #2, and #3, and all the required forms. Haskins, Inc. identified Cabana Construction as their Directional Drilling Sub -Contractor in the Bid. Johnson Engineering contacted five (5) references provided in the Bid submitted by Haskins, Inc. and two (2) of the references provided by Cabana Construction. These references confirmed the referenced projects and contract amounts and had good comments. These references also verified that Haskins, Inc. and Cabana Construction meet the required contractor's qualifications identified in the Project Specifications. In addition to this research, Haskins, Inc. is currently one (1) of the six (6) approved underground utility contractors on Collier County Contract #14-6213 Annual Contract for Underground Utilities and General Contractors and has performed many utility projects for Collier County Public Utilities. Furthermore, Johnson Engineering has personally worked with both Haskins, Inc. and Cabana Construction on various projects of similar scope and magnitude in Collier County and other surrounding counties in southwest Florida. This construction project is unique due to the large diameter water main installation, the directional drill installation within the US-41 (State -maintained) right of way, and the installation of the pipeline within the existing residential neighborhood. It will require extensive knowledge and experience in these fields for a successful project and to minimize risk to the County. It is imperative that the project is awarded to a responsive and responsible bidder capable of performing the work in accordance with the construction plans, specifications, and permit requirements. Based upon the Bid Tabulation Analysis performed by Collier County, the research performed by Johnson Engineering, and the past work experience Haskins, Inc. has with Collier County and Johnson Engineering, we find that Haskins, Inc. appears to be a responsive and responsible bidder. Subject to concurrence with Collier County's Purchasing and Contracts Administration Division, and Haskins, Inc. furnishing the appropriate bonding and other required insurances, we believe selection of the next lowest bidder, Haskins, Inc. by Collier County for the intended wok contained within the bid documents to be the appropriate choice. Packet Pg. 772 11.K.c Ms. Sue Zimmerman, CPM Re: Design Entity's Letter of Review & Acknowledgement Collier County Solicitation No.: 20-7752 Project: Hickory Road Water Main Improvements June 17, 2020 Page 4 Should you have any questions, or require additional information, please let us know. Very truly yours, JOHNSON ENG EKING, INC. f Michael S. Dickey, P.E. Director of Utility Services WHS/ljb Enclosure 20149700-247 Packet Pg. 773 20.T152 Bid Opened BY: 6 Bro;;nT4a: NDNDBYBOADWFTBBMFINIMBBOVBMBNra w4� dBy reFaa9an Bid Due Dete: Mdy 1. 2020 @ 3:00 pm BID TABULATION SECTION 2: WATER SYSTEM ® FINIMgm fflmmogmll Foommm � �KEEE=i F . s1 ENGINEERS ESTIMATE $ ,B0,0ao.00 $ ,eo,0ao.00 $ ]5,000.00 $ ]S,o00.00 nm$15".. oa9.00azs o0l2.00350.000]So0250.00,025W,]ao.00 $ 30U,D $ 28,200.00 $ 300A0 $ 19,200.00 $ 60.M $ 20,040.00 $ Koo $ +9,980.00 $ 60.00 $ 30,900.00 s +so oo s 4soo.00 $ 200.00 $ 27,000.00 $ 200.W $ 11,2— SECTION36UBTOTAL $ 549,4]6.23 1 E 561,195.50 $ 528,543.74 $ 40],fi49.00 $ 3fi4,]10.00 $ 335,262.00 IE 300,505.90 $ 420,30.5.00 $ 605,633.05 $ 254,612.00 $ 715,945.00 LL 431,4]6.00 $ 579,450.00 1 1$ 399,003.00 E 1-,362.00 $ 470,]5].00 4: ALLOWANCE Oumafs Nlowanoe for O.mafs Usa as Directed: mu any a1 tM ormels elrecti•n 19 T.M $100,000 $ 100,0oo.o0 $100,000 $ 1oo,0oo.00 $100,000 E 100,000.00 $100,000 $ 100,000.00 $100,000 $ 100,000.00 E100,000 E 100,000.00 $100,000 E ioo,000.00 $1o0,000 $ ,00,000.00 E100,000 $ ioo,000.o0 E100,000 $ 100,000.00 E100,000 $ 100,000.00 E100,000 $ 100,000.00 E100,000 E 100,000.00 $100,000 E 100,000.00 $100,000 E 100,000.00 BID SUMMARY SECTION 1 GENERAL SUBTOTAL: $ 167,569.46 SECTION 2 WATER SYSTEM SUBTOTAL: $ 533,355.00 SECTION 3 RESTORATION SUBTOTAL: $ 50,476.23 SECTION 4 OWNER'S ALLOWANCE: $ 100,000.00 BID TOT E 1,350,400.69 $100,000 $ 100,000.00 S 100,000.00 S 100,000.00 $ 100,000.00 § 100,000.00 S 100,000.00 f 1 00,000.00 $ 100.000.00 f 1 00,000.00 § 100,000.00 § 100,000.00 $ S 100,000.00 f 00,000.00 S 100.000.00 E 100,000.00 $ 102,300.00 4,4 32264.o ,3 E 159,050.00 E 225,000.00 $ 199,017.00 E 451155.00 $ ,000.00 $ 206,900.00 $ 170,000.00 $ 613,751.00 ,, 1,034,772.00 1,039,271.00 E 1,126,295.0072 $ 561,195.50 $ 528,543.74 $ 487,848.00 $ 364,710.00 $ 335,282.00 $ 300,505.96 11 $ 420, 1 $ 605,633.05 $ 254,812.00 58450 $ 41,476.00 39003.000 ,0 624,362.00 $ 470,757.00 $ 100,00000 . $ 100,000.00 $ 100, $ .0 ,6 E 100,000.00 $ 0,0000 E 100,000.00 $ 1000.00 E 100,000.00 $ 100,000.00 1,499,32.2 $ 1,574, 602.10 ,686,712.00 2,9420 .01,377,2.50 802,843.00 $ 1,920,7705.0 1,970,533.00 1,867,052.00E a Packet Pg. 7 47 11.K.c Collier County Public Utilities Solicitation No. 20-7752 Hickory Road Water Main Improvements Cougar Contracting, LLC Reference Call Log Requirements Identified in Supplemental Specification #3 Contractor's Qualifications: The Contractor needs to demonstrate extensive experience of the following: A. Installing large diameter water mains within the past five (5) years. No reference could verify. 6/16/2020 B. Extensive experience and equipment to complete the directional drill operations under US 41. Performed at least two (2) directional drills within a State Right -of -Way within the past five (5) years. No reference could verify. C. Experience installing pipelines in neighborhoods within the past five (5) years. No reference could verify. Information Provided by the Bidder (Cougar Contracting, LLC - . • Project Name/ Project Project Contact Contact Phone/Email Contact Comments Date Reference # Owner Contacted #1 Collier County David Steger 713-332-7246) Attempted David Steger at the phone7.ree3 hone calls were attem ted, one 1 voicemail was left, and one 1 email was p p () ( ) Collier County Board of Project Manager dsteger(o�manhattanconstruction.com number and email address provided sent to phone number and email address provided by the bidder. Sports Complex Commissioners. Manhattan Construction by the bidder. #2 JMD Developments David Fernandes 32-6 239-732-6669 Attempted David Fernandes at the p •Three (3) phone calls were attempted, one (1) voicemail was left, and one (1) email was Antilles Investments Field Manager dfernande bild.com phone number and email address sent to phone number and email address provided by the bidder. LLC The Henning Group provided by the bidder. • Could not confirm any of the required qualifications per Supplemental Specification #3 #3 Fort Myers H. John Flinn .0/3 ( ) Honda of Fort Automotive President Manager 727-638-5981 John Flinn at the reference phone • The project was completed on time and within budget, had no issues with the work, p � p g 5/28/2020 Myers Management Morgan Auto Group jflinn(c�morganautogroup.com number provided b the bidder. p y performed satisfactory review/submittals, project went very smooth, and would highly LLC recommend this company. • Could not confirm any of the required qualifications per Supplemental Specification #3 #4 S-H Naples Austin Thomas 239-675-9663 Austin Thomas at the reference phone (0/3). Discovery Village Development Field Manager athomas(c�webild.com number provided by the bidder. • The project was completed on early and within budget, had no issues with the work, 5/28/2020 Commons Propco LLC The Henning Group performed satisfactory review/submittals, project went fairly smooth and had one change order. #5 Lee-Tamiami Adis Ibranovic 904-208-2026 Attempted Adis Ibranovic at the phone •Three (3) phone calls were attempted, one (1) voicemail was left, and one (1) email was Parkside at Estero LLC Project Manager aibranovic(c�favergray.com number and email address provided sent to phone number and email address provided by the bidder. FaverGra b the bidder. #6 Big Corkscrew Collier County David Pabor Florida Division 813-279-8250 8250 Attempted David Pabor at the phone • Three 3 hone calls were attempted, one 1 voicemail was left, and one 1 email was () p p () ( ) Island Regional Board of Manager d�abor(a�3-279 c.com number and email address provided sent to phone number and email address provided by the bidder. Park Commissioners Astra Construction by the bidder. E 0 a E a� �a 0 0 0 x N It 00 N 7 Packet Pg. 775 11.K.c C;o er (Z-ou ty - fff,ir*drative Services Departmexrt curement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Solicitation Title: Hickory Road Water Main ImprovemeL Date: Brett A. Dean (JEI) 5/28/2020 Bidder's Name: Cougar Contracting, LLC Phone: 1 239-275-0746 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: Honda of Fort Myers Project Location' 3550 Colonial Blvd, Fort Myers, F1 ----- Project Description: Site and underground utilities for new 3-story dealership Completion Date: 12/3/2018 - 12/19/2019 Contract Value: Fort Myers H. Automotive Management LI 3031 North Rock Point Dr Ste. 770, Tampa, FL.Phone: $ 2,449,588.00 727-638-5981 Project Owner/Title: Owner's Address: Owner's Contact Person: John Flinn - President E-Mail: Iflinn@morganautogroup.com 1. Was project completed timely and within budget? (If not, provide detail) 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) VF(Lv NIUL 3. Was the construction process performed satisfactorily? (If not, provide detail) tZ ` 1= ASE D 6" htµ 4. Did the process run smoothly? Were there any changes? Describe below. ES 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Cv 6K M EYES I P A I (MC + oa/ 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? t✓ 7. Additional comments: HMI r H Ll 2 ECU MMe W D 7H-Is {d,�R Ny, -T[- e;� C6MMVViC hlL F- Vy�lt� LL 1 IFo (,l'UW w") [5 Ui c5y_P t} 1 kp ( C Pfu M Aril -tH c- Gl . Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 776 11.K.c 8. Did the project include the installation of any large diameter (12-inch or larger) WM, FM, or IQ Mains? quo 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? No 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? 0 Packet Pg. 777 476Y I;0U- .tY Adrt>ir>istr . Servioes Department =u4:`m—,rit Szr 2s DMmn VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Brett A. Dean (JEI) Solicitation Title: Hickory Road Water Main Improvements Date: 5/28/2020 Bidder's Name: Cougar Contracting, LLC Phone: 239-275-0746 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name' Discovery Village Commons Project Location' 335 Sierra Meadows Blvd, Naples, FL 33928 Project Description: Site and underground utilities for assisted living facility Completion Date: 5/31/2018 - 3/18/2020 Contract Value: $ 2,601,612.00 Project Owner/Title: S-H Naples Development Propco LLC Owner's Address: 7599 River Center De. Ste. 200 Bonita Springs, Phone: 239-675-9663 Owner's Contact Person: Austin Thomas - Field Manager E-Mail: athomas webild.com 1. Was project completed timely and within budget? (If not, provide detail) �25 �e-cr- f-' sj-(� t e _111cia- r- b "C t 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) 3. Was the construction process performed satisfactorily? (If not, provide detail) �6 g ei - 4. Did the process run smoothly? Were there any changes? Describe below. L-Aft� t nor C hov►� S. Was the contract closeout process performed satisfactorily? (If not, provide detail) 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? i rl o c C lkovt n'e!'. - 7. Additional con Tab 2 - Appendix H2 - Template - DELORA Vendor Reference Check Log - rev 02-14-20 11.K.c Packet Pg. 778 11.K.c 8. Did the project include the installation of any large diameter (12-inch or larger) WM, FM, or IQ Mains? " 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? � CS, b "+ N d'r t' /N S +ate 20 W 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? y2sl as5is^ter,( 1 �Vk�� U Ofv Packet Pg. 779 11.K.c Collier County Public Utilities Solicitation No. 20-7752 Hickory Road Water Main Improvements Haskins, Inc. Reference Call Log Requirements Identified in Supplemental Specification #3 Contractor's Qualifications: The Contractor needs to demonstrate extensive experience of the following: A. Installing large diameter water mains within the past five (5) years. Haskins, Inc. Reference #1 verified. 6/16/2020 B. Extensive experience and equipment to complete the directional drill operations under US 41. Performed at least two (2) directional drills within a State Right -of -Way within the past five (5) years. Cabana Construction Reference #1 and #2 verified. C. Experience installing pipelines in neighborhoods within the past five (5) years. Haskins, Inc. Reference #1 verified. Information Provided by the Bidder Haskins, Inc. - • Project Name/ Project Owner Project Contact Contact Phone/Email Contact Comments 7.e Date Reference # Contacted nce did confirm large diameter pipe was installed and installed a pipeline within an #1 existing residential neighborhood (2/3). BSU-RO WTP Bonita Springs Utilities (BSU) Don Woodruff Bonita Springs Utilities 239-992-0711 No Email Provided Called Don Woodruff at the reference number provided by the bidder. .The project was completed on time and within budget, had no issues with the work, 6/8/2020 WellfiU- Expansion p performed satisfactory review/submittals, project went very smooth, had minor warranty with an ARV but Haskins responded in timely manner. • Could not confirm installation of large diameter pipe, directional drills in a state ROW, or #2 Robbie Powell pipeline in a residential neighborhood (0/3). FGCU Lake Front Wright Construction Group er Project Manager g 239-481-5000 No Email Provided Called Robbie Powell at reference number provided by the bidder. • The project was completed on time and within budget, had no issues with the work, 6/12/2020 Development Wright Construction Group performed satisfactory review/submittals, project went very smooth, referred to Haskins as "Good Company". • Could not confirm installation of large diameter pipe, or directional drills within State ROW #3 Shannon Bassett Called Shannon Bassett at different as listed in the required qualifications per Supplemental Specification #3 (1/3). Memorial Pathway Collier County GMD President Manager 2Email Provided No Email Provided phone number than provided by the •The project was completed on time and within budget, had no issues with the work, 6/12/2020 on Vanderbilt Drive Collier County GMD bidder. performed satisfactory review/submittals, project went very smooth, and would highly recommend this company. • Could not confirm installation of large diameter pipe, or directional drills within State ROW Called Andrew Zuckerman at the as listed in the required qualifications per Supplemental Specification #3 (1/3). #4 Lynx Zuckerman at Andrew Zuckerman 954-481-3700 reference phone number and was not 6/11/2020 Venetian Pointe Naples, LLC Lynx Zuckerman No Email Provided available, however Ryan Zuckerman • The project was completed on time and within budget, had no issues with the work, able to verify project details. performed satisfactory review/submittals, project went very smooth, and has already referred company to others. • Could not confirm Installation of large mains or drills within State ROW as listed in the #5 required qualifications per Supplemental Specification #3 (1/3). Village of Entrada DR Horton, Inc. SWFL James Inc.2Email DR Horton, nc. SWFL Provided No Email Provided Called James Rd b at reference number provided by the bidder. . The project was completed on time and within budget, had no issues with the work, 6/12/2020 Phase 2A and 2B performed satisfactory review/submittals, project went very smooth, says Haskins has "good communication". E 0 a E a� �a 0 0 0 x N It 00 N Packet Pg. 780 11.K.c Collier County Public Utilities Solicitation No. 20-7752 Hickory Road Water Main Improvements 6/16/2020 Information Provided b the Subcontractor Cabana Construction Project Name/ Project Owner Project Contact Contact Phone/Email Reference # Contact Information from Reference Verification Comments Date Contacted • Could not confirm Installation of large mains or any pipe within neighborhood however did include drills within State ROW as listed in the required qualifications per #1 cn 8 Street Wright Construction Neil Monkman 239-462-7371 Called Neil Monkman at the reference Supplemental Specification #3 (1/3). 6/15/2020 Improvements Prime Contractor ( ) Wright Construction g Neil.monkman we fl.com @ g number provided b the bidder. p y • The project was completed on time and within budget, had no issues with the work, p � p g performed satisfactory review/submittals, project went very smooth, said to have their locates on time. • Could not confirm Installation of large mains or any pipe within neighborhood however did include drills within State ROW as listed in the required qualifications per #2 D.N. Higgins Mike Lobello 239-273-0423 Called Mike Lobello at reference Supplemental Specification #3 (1/3). Emergency Tamiami Trail (Prime Contractor) Project Manager D.N. Higgins Mikel@dnhiggins.com number provided by the bidder. •The project was completed on time and within budget, had no issues with the work, 6/15/2020 performed satisfactory review/submittals, project went very smooth, highly recommend their business. c as aEi 0 a E c m �a �a 0 0 x N It 00 N r Packet Pg. 781 11.K.c Co r County Administrative Services Departrnent Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/08/2020 Bidder's Name: Haskins, Inc. Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: BSU-RO WTP Wellfield Expansion Project Location: I Bonita Springs, FL Project Description: Install 30" Raw Water Line and Conduits via open cut, directional drill and jack and bore. Completion Date: 07/15/2018 Contract Value: $ 3,000,000.00 Project Owner/Title: Bonita Springs Utilities (BSU) Owner's Address: 11900 E. Terry Street Phone: 239-992-0711 Owner's Contact Person: Don Woodruff E-Mail: None provided. 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. Yes, minor changes due to field conditions. Haskins, Inc. followed the proper change procedure. S. Was the contract closeout process performed satisfactorily? (If not, provide detail) No, but was not caused/due to Haskins, Inc. 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? Yes, one ARV at material transition. Haskins, Inc. responded in a timely manner. 7. Additional comments: See next sheet. Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 782 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, or IQ Mains? Yes. Installed 30" raw water main via open cut, directional drill, and jack and bore methods. 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? Yes. Within County and City ROW, but not within a State ROW. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? Yes. 30" pipeline through both an existing and proposed (under construction) residential neighborhood. Packet Pg. 783 11.K.c Cod e,r County Administrative Services Departrnent Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/12/2020 Bidder's Name: Haskins, Inc. Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: FGCU Lake Front Development Project Location: I Fort Myers, FL Project Description: Utility and Drainage Installation, Road and Pond Construction. Completion Date: 11/14/2017 Contract Value: $ 366,511.80 Project Owner/Title: Wright Construction (on Behalf of FGCU) Owner's Address: 5811 Younquist Rd, Fort Myers, FL Phone: 239-481-5000 Owner's Contact Person: Robbie Powell E-Mail: None Provided 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. Yes, but not due to Haskins, Inc. 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Yes. 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? None. 7. Additional comments: Good Company Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 784 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, or IQ Mains? No• 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? No. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? Through existing college dorms Packet Pg. 785 11.K.c Co r County Administrative Services Departrnent Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/12/2020 Bidder's Name: Haskins, Inc. Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: Memorial Pathway on Vanderbilt Dr Project Location: Naples, FL Project Description: Utility installation and Road construction Completion Date: 07/03/2017 Contract Value: $ 2,341,044.22 Project Owner/Title: Collier County GMD Owner's Address: 3339 Tamiami Tr Naples, FL Phone: 239-253-3170 Owner's Contact Person: Shannon Bassett E-Mail: None Provided 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. Yes, not due to Haskins, Inc. 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Yes 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? None 7. Additional comments: Staffed well Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 786 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, or IQ Mains? Unsure. 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? None on this project, but have seen them perform drills on other projects. Unsure if in state ROW. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? Yes. Existing. Packet Pg. 787 11.K.c Cod e,r County Administrative Services Department Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/11/2020 Bidder's Name: Haskins, Inc. Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: Venetian Pointe Project Location: I Fort Myers, FL Project Description: Utility and Drainage Installation, Road and Pond Construction. Completion Date: 01/07/2018 Contract Value: $ 6,590,310.05 Project Owner/Title: Lynx Zuckerman at Naples, LLC Owner's Address: 6131 Lyons Road, Suite 200 Coconut Creek, FL Phone: 239-954-481-3700 Owner's Contact Person: Ryan Zuckerman E-Mail: None Provided 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. Yes, minor changes due to field conditions, not due to Haskins, Inc. 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Yes. 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? Yes. Yes. 7. Additional comments: Did excellent work, would hire them again, has already referred to other developers. Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 788 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, or IQ Mains? Does not recall. 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? Yes. Within County ROW, but not within a State ROW. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? Yes. Through a proposed development under construction. Packet Pg. 789 11.K.c Co r County Administrative Services Departrnent Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/12/2020 Bidder's Name: Haskins, Inc. Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: Village of Entrada Phase 2A and 2B Project Location: Cape Coral, FL Project Description: Complete Site Development Completion Date.. In Progress Contract Value: $ 3,200,000.00 Project Owner/Title: DR Horton, Inc. SWFL Owner's Address: 10541 Six Mile Pkwy, Fort Myers, FL Phone: 239-225-2610 Owner's Contact Person: James Ratz E-Mail: None Provided 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. Yes, minor, not due to Haskins, Inc. 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Yes 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? None 7. Additional comments: Very good company, good communication, whole process was smooth. Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 790 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, or IQ Mains? No• 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? No. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? Yes. Portion of the development was partially complete. Packet Pg. 791 11.K.c Co r County Administrative Services Departrnent Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/15/2020 Bidder's Name: Cabana (Subcontractor to Haskins, Inc.) Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: 8th Street Improvements Project Location: Naples, FL Project Description: Directional Drill Completion Date: 2/18/2020 Contract Value: $ 237,590.00 Project Owner/Title: Prime Contractor - Wright Construction Owner's Address: Naples, FL Phone: 239-462-7371 Owner's Contact Person: Neil Monkman E-Mail: Neil. monkman@wcgfLcom 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes, very well. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. Yes, but not due to Cabana. 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Yes 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? None 7. Additional comments: Did a great job. Locates on time. Went very smooth. Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 792 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, Or IQ Mains? No. 10-inch HDPE force main installed. 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? Yes. Portion was within US-41. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? No. Packet Pg. 793 11.K.c Co r County Administrative Services Department Procurement Services Division VENDOR REFERENCE CHECK LOG Solicitation No.: 20-7752 Reference Check by: Billy Saum (JEI) Solicitation Title: Hickory Rd Water Main Improvements Date: 06/15/2020 Bidder's Name: Cabana (Subcontractor to Haskins, Inc.) Phone: 239-947-1846 Design Entity: Johnson Engineering, Inc. REFERENCED PROJECT: Project Name: Emerg. Tamiami Trail Project Location: Naples, FL Project Description: Directional Drill Completion Date: 10/17/2019 Contract Value: $ 22,050.00 Project Owner/Title: Prime Contractor - D.N. Higgins Owner's Address: 4420 Mercantile Ave, Naples, FL Phone: 239-273-0423 Owner's Contact Person: Mike Lobello E-Mail: Mikel@dnhiggins.com 1. Was project completed timely and within budget? (If not, provide detail) Yes. 2. Was the submittal/review process performed satisfactorily? (If not, provide detail) Yes. 3. Was the construction process performed satisfactorily? (If not, provide detail) Yes. 4. Did the process run smoothly? Were there any changes? Describe below. Yes. No changes. 5. Was the contract closeout process performed satisfactorily? (If not, provide detail) Yes 6. Any warranty issues since closeout? Were they responded to and performed satisfactorily? None 7. Additional comments: One of the top directional drill contractors to work with. Highly recommended. Tab 2 - Appendix H2 — Template - DELORA Vendor Reference Check Log - rev 02-14-20 Packet Pg. 794 11.K.c 8. Did the project include the installation of any large diameter (16-inch or larger) WM, FM, or IQ Mains? No. 6-inch force main installed. 9. Did the project include a directional drill/bore? If so, which Right -of -Way was it within? Yes. US-41. 10. Did the project include the installation of pipeline in a residential neighborhood? If so, was it an existing neighborhood or proposed? No. Packet Pg. 795 DocuSign Envelope ID: FAE8BD2E-7C9D-404C-B953-E654AD79AF38 coer county Administrative Services Department Procurement Services Division Date: June 22, 2020 Notice of Recommended Award Solicitation: 20-7752 Title: HICKORY ROAD WATER MAIN IMPROVEMENTS Due Date and Time: May 5, 2020 at 3:00 p.m. 11.K.d Respondents: Company Name City County State Bid Amount Responsive/ Responsible Cougar Contracting, LLC Fort Myers Lee FL $1,350,400.69 Y/N Haskins, Inc. Bonita Springs Lee FL $1,377,246.50 Y/Y Thompkins Contracting, Inc. Lehigh Acres Lee FL $1,395,362.75 Y/Y PWC Joint Venture LLC Fort Myers Lee FL $1,405,129.00 Y/Y Douglas N. Higgins, Inc. Naples Collier FL $1,426,975.00 Y/Y GT General Contractors LLC Coral Springs Broward FL $1,446,392.00 Y/Y R.P. Utility & Excavation Corp. Hialeah Miami -Dade FL $1,499,342.24 Y/Y Andrew Sitework LLC Fort Myers Lee FL $1,574,660.00 Y/Y Mitchell & Stark Construction Co., Inc. Naples Collier FL $1,600,682.12 Y/Y Metro Equipment Service, Inc. Miami Miami -Dade FL $1,686,712.00 Y/Y Intercounty Engineering, Inc. Pompano Beach Broward FL $1,742,942.00 Y/Y Quality Engineering, Inc. Naples Collier FL $1,802,843.00 Y/Y Strickler Bros. Underground, Inc. Fort Myers Lee FL $1,869,400.00 Y/Y American Pipeline Construction LLC Miami Miami -Dade FL $1,920,775.00 Y/Y Coastal Concrete Products, LLC. Fort Myers Lee FL $1,970,533.00 Y/Y Utilized Local Vendor Preference: Yes No N/A On April 2, 2020, the Procurement Services Division posted Invitation to Bid 20-7752 for construction of HICKORY ROAD WATER MAIN IMPROVEMENTS. The County issued 28,694 notices and One Hundred Twenty -Six (126) bid packages were viewed. On May 5, 2020 the County received fifteen (15) bid responses as summarized above. Staff reviewed the bids received and determined that Cougar Contracting, LLC was not responsible because they did not meet the minimum required experience (Contractor Qualifications — Exhibit J — Technical Specs) of the bid documents. It was further reviewed and determined that Haskins, Inc. is the lowest responsive and responsible bidder. Staff therefore recommends that the contract be awarded to HASKINS, INC., the lowest responsive and responsible bidder, for a total contract amount of $1,377,246.50. Required Signatures Project Manager: Benjamin Bulle DocuSigned by: mivu N. 1&3DW17�6'12129DD408 Procurement Strategist: Sue Zimmerman: DocuSigned bv: �noan�nonnasn no N r.+ c d d 0 a E c M L M 0 0 0 Y x N 00 N Packet Pg. 796 DocuSign Envelope ID: FAE8BD2E-7C9D-404C-B953-E654AD79AF38 11.K.d Procurement Services Director: DOCUSigned by: 50. fiftU44 6/22/2020 Date Packet Pg. 797 CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with Haskins, Inc. ("Contractor") of Florida Profit Corporation, a 10956 Enterprise Avenue, Bonita Springs, FL 34135, authorized to do business in the State of Florida, to perform all work ("Work") in connection with Hickory Road Water Main Improvements, Invitation to Bid No. 20=7752 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Johnson Engineering, Inc., the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, f or the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment Cl"d services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount"), in accordance with the terms of this Agreement: One Million Three Hundred Seventy -Seven Thousand Two Hundred Forty -Six Dollar and Fifty Cents ($1,377,246.50) Section 4. Bonds. A. If applicable, the Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit B-1 and B-2, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www,fms.treas.gov/c570/c570,html#certified. Should the Contract Amount be less i Construction Services Agreement: Revised 072118 (vti) k�0 than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liquidated Damages. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The "Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date, No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within Two Hundred Forty (240) calendar days from the Commencement Date (herein "Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within Thirty (30) calendar days after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, One Thousand Six Hundred Sixty -Five Dollars ($1,665.00) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion, The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday 2 Construction Services Agreement: Revised 072118 (v6) ���i or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non -delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed upon, attached hereto and made a part of this Agreement for Solicitation 20-7752 "Hickory Road Water Main Improvements". Exhibit A-1 Exhibit A-2 Contractor's Bid Schedule 3 Construction Services Agreement: Revised 072118 (v6) Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions ❑ Applicable ® Not Applicable The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 20=7752 "Hickory Road Water Main Improvements". The complete contract documents, including Addendum with attachments, are available on the County's on-line bidding system: https://www.bidsync.com/bidsync-cas/, which the parties agree comprise the final integrated agreement executed by the parties. Sections corresponding to any checked box (®)expressly apply to the terms of this Agreement and are available through the County Is on-line bidding. ®Exhibit J: Technical Specifications ®Exhibit K: Permits ]Exhibit L: Standard Details ®Exhibit M: Plans and Specifications prepared by Johnson Engineering, Inc. ®Exhibit N: Environmental Health and Safety Requirements for Construction Projects Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, FL c/o Public Utilities Engineering &Project Management Division 3339 Tamiami Trail East Naples, Florida 34112 Attn: Benjamin Bullert, Principal Project Manager Phone: (239) 252-2583 Email: Benjamin. Bullert(@colliercount f�l.gov_ B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Haskins, Inc. 10956 Enterprise Avenue Bonita Springs, FL 34135 Attn: Ryan MacPhee, Vice President Phone: (239) 947-1846 Email: Rmacphee6E haskinsinc.net C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. 4 ��F Construction Services Agreement: Revised 072118 (v6) Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreement. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or irore of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. Construction Services Agreement: Revised 07211II (v6) Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. 6 Construction Services Agreement: Revised 072118 (v6) ��� I IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s) indicated below. CONTRACTOR: TWO WITNESSES: Haskins, Inc. FIRST WITNESS Mabel Lago By: Wae Ryan M Phee,icr: Print Name and Title SECON ESS Lianet Arrieta Print Name Date: ATTEST: Crystal K. Kinzel, Clerk of Courts & Comptroller BY: Approved as to Form and Legality: Assistant County Attorney Print Name President Date OWNER: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY FLORIDA MN Burl L. Saunders, Chairman 7 Construction Sei vices Agreement: Revised 072118 (4) EXHIBIT A-1: CONTRACTOR'S BID SCHEDULE (FOLLOWING THIS PAGE) 8 Construction Services Agreement: Revised 072118 (v6) ITB# 20-7752 "Hickory Road Water Main Improvements BID SCHEDULE Haskins Inc. Item Item No. Description Unit Quantity Unit Cost Total Cost SECTION 1: GENERAL UNIT PRICE EXTENDED PRICE ITEM NO. DESCRIPTION UNIT 1 Mobilization / Demobilization LS $ 40,000.00$ 40,000.00 2 Maintenance of Traffic OESTv LS $ 24,000.00 $ 24,000,00 3 Survey Layout & Record Drawings LS $35,000.00 $ 35,000.00 4 Pre -Construction & Post -Construction Videos LS $ 3$00.00 $ 33300,00 SECTION 1 SUBTOTAL: $ 102,300.00 SECTION 2: WATER SYSTEM ITEM NO. DESCRIPTION EST. QUANT. UNIT UNIT PRICE - EXTENDED PRICE 5 a. b. c. d. Install PVC Water Main Pipelines (Labor Only) 24" PVC DR18 Water Main 20" PVC DR18 Water Main 16" PVC DR18 Water Main 8" PVC DR18 Water Main 385 LF 41660 LF 571 LF 183 LF $ 58.00 $ 22,330,00 $ 50.00 $ 233,000,00 $ 40.00 $ 22,840.00 $ 32.00 $ 51856,00 6 a. b. c. d. e. Install Gate Valve and Box (Labor Only) 30" Gate Valve 24" Gate Valve 20" Gate Valve 16" Gate Valve 8" Gate Valve 1 1 6 8 3 EA EA EA EA EA $ 14,500.00 $ 81100,00 $ 5,500.00 $ 3,300.00 $ 1,950.00 $ 14,500,00 $ 8,100.00 $ 33,000,00 $ 26,400400 $ 51850,00 7 Directional Drill DR 11 (Vanderbilt Beach Dr. @ Station 4+58 to 12+51) (Labor Only) 1 LS $ 102,000,00 $ 102,000,00 8 9 10 Subaqueous Crossing (Carica Road @ Station 8+50) (Labor Only) Install Air Release Valve Install Fire Hydrant AssemblyLabor Only)11 1 2 LS EA EA $ 15,000,00 $ 31300,00 $ 31625,00 $ 15,000.00 $ 61600400 $ 39,875.00 11 a. b. Install Bacteriological Sample Point Temporary Permanent 4 EA 4 EA $ 21500,00 $ 10,000,00 $ 2,800.00 $ 11*200,00 12 a. b. c. Connect to Existing Water Main 30" Water Main Connection 16" Water Main Connection 8" Water Main Connection 1 EA 5 EA 4 EA $ 81100,00 $ 5,500.00 $ 5,400.00 $ 8,100.00 $ 27,500.00 $ 21,600,00 $ 613,751400 SECTION 2 SUBTOTAL: SECTION 3: RESTORATION ITEM NO. DESCRIPTION EST. QUANL UNIT' 13 General Restoration 1 LS 14 Abandon & Remove Existing Wafter Main a. Abandon & Remove 8" Water Main 33 LF b. Abandon & Remove 12" Water Main 41626 LF 15 Abandon & Grout Existing 12" Main 11290 LF 16 DrivewayRestoration a. Concrete 761 SY b. Asphalt/Gravel 450 SY c. Brick 427 SY 17 Sidewalk Restoration (FDOT Right of Way) 157 SY 18 RoadwayRestoration a. Vanderbilt Station 4+50 94 SY UNIT PRICE EXTENDED PRICE $ 80,000.00 $ 80,000.00 $ 20.00 $ 660.00 $ 16,75 $ 77,485,50 $ 9.00 $ 11,610.00 $ 70.00 $ 53,270,00 $ 108.00 $ 48,600.00 $ 160.00 $ 68,320,00 $ 95.00 $ 14,915.00 $ 185.00 $ 17,390.00 anderbilt @ Station 6+50 (FDOT 64 SY OM j4d. icko & Cassena 333 SY icko & Tu elo 333 SYick &515 SYCarica & Goodlette 30 SY Goodlette (South bound) @ Station 135 SY 9' 2+00 Goodlette (North bound) @ Station 56 SY h' 2+00 SECTION 3 SUBTOTAL: PION 4: ALLowANc:t Owner's Allowance for Owner's Use as Directed: This Owner's Allowance will be used only at the Owner s direction to accomplish work due to unforeseen conditions and/or as directed by the Owner. Inclusion of the Owner's Allowance as part of the T&M 19 Contract Price is not a guarantee that the Contractor will be paid any portion or full amount of the Allowance. Expenditures of Owner's Allowance will be made through Change Order with proper documentation of Time and Materials supporting the $ 390.00 $ 24,960,00 $ 95.00 $ 31,730.00 $ 95.00 $ 31,635.00 $ 90.00 $ 46,350.00 $ 540.00 $ 16,200.00 $ 0 $ 22,950.00 $0 E $ 15,120,00 $ 561,195,50 AL:I BID SUMMARY SECTION 1 GENERAL SUBTOTAL: SECTION 2 WATER SYSTEM SUBTOTAL: SECTION 3 RESTORATION SUBTOTAL: SECTION 4 OWNER'S ALLOWANCE: BID TOTAL: $100,000 $ 100,000.00 $ $613751.00 $5610195050 $100,000.00 ig $I,377,246.50 EXHIBIT A=2: CONTRACTOR'S BID SUBMITTAL FORMS AND ADDENDUM (FOLLOWING THIS PAGE) 9 Construction Services Agreement: Revised 072118 (v6) Email: Sr�e.L.irn77rn�an(cr�callierc��ntco� v.net Telephone: 239-252-8034 Administrative Seivices Department Procurement services Division IUlemorandum Date: April 17, 2020 Frorrr: Sue Zimmerman, Procurement Strategist To; Interested Parfies Subject: Addendum # 1 - #20o7752 - HICKORY ROAD WATER MAIN IMPROVEMENTS I -his addendum has been issued for the following item(s) identifying clarifications, changes, deletions, or additions to the original solicitation documents and bid schedule for the above referenced solicitation. Pre -Bid Meeting Minutes and "Call -in" Sign -in Sheets: ® 207752 -Addendum #1 -Pre-Bid Meeting Minutes and Sign -in Sheets, attached. Additional Documents: ® 20-7752 — Exhibit K — Permits: Copies of approved FDOT Utility permit; FDEP ERP permit; ACOE permit information; and FDEP water distribution permit. ® 20-7752 —List of Materials being provided by Collier County. CC: Ben Bullert, Principal Project Manager Please acicn (Slg n F-lacking Inc of this Addendum and include with your bid. hee, Vice President 0�/05/20 Date (Name of Firm) If you require additional information, please post a quesfiion on BidSync on-line or contact me using the above contact information. Email: SUe.Zimmernian ri7c Ilie1county40vA1U.4 �e(ephone: 239-25M034 Administrative Services Department Procurement Seivices Division ADbENDUM �f 2 Memorandum Date; April 21, 2020 From: Sue Zimmerman, Procurement Strategist To: interested Parties Subject: Addendum � � - tt20�7752 -HICK®RY R®AD 11VATER MAIN IMPRC7VEMENTS This addendum has been issued for the following items) identifying clarifications, changes, deletions, or additions to the original solicitation documents and bid schedule for the above referenced solicitation. Revised Document: ® 20-7752 -List of Materials being provided by Collier County -The attached revised List of Materials now includes additional material to complete the fire hydrant assemblies that Collier County will be providing, Also please be reminded that all other material and Fittings required that is not on the list will be the responsibility of the contractor to provide. CC: Ben Bullert, Principal Project Manager Please aclrn (Sig of this Addendum and include with your bid. n acPhee, Vice President 1 _r Haskins Inc. {Name of Firm) If you require additional information, please post a question on BidSync on-line or contact me using the above contact information. O 7�i O . tY Administrative Services Department Procurement Services Division Memorandum Date: April 2li, 2020 Email: SLISS,Zitllfilet l LavicoIl etc��infi}ac(ov.net i e(ephonw 239-252-8034 A[�pENIJUM # 3 From: Sue Zimmerman, Procurement Strategist To; Interested Parties Subject: Addendum #t` 3 - #20-7752 -HICKORY ROAD WATER MAIN IMPROVEMENTS This addendum has been issued for the following itern(s) identifying clarifications, changes, deletions, or additions to the original solicitation documents and bid schedule for the above referenced solicitation. QID CfARIFICAT(ON INFORMATION: ® 20-7752 -Clarifications: ® All asphalt repair should be type 5P9.5 not SP9 as previously stated. ® Any culverts damaged during installation of watermain are subject to be replaced per Cailier County standards which includes Reinforced Concrete Pipe (RCP) and Mitered End Sections. Cost to repair culverts should be incidental to the pipeline installation item. ® Please refer to the Collier County Right of Way handbook for all requirements for replacing the culverts, htt s:/lyvJV�l.coliiercaunty�fl.,UOVyotar-�overrn3ient/divisions-a:eldevelorJment-reviewlrighfi-of w -row-per►Hitting-Ind-insl�ect�on-sectionl�lht-of-4wa -irow�_grdinances-resolutions-artdI•row-rae. ® Final acceptance of replaced culverts will be provided by the Collier County Right -of --Way inspector. CC: Ben Bvilerfi, Principal Project Manager Please acknowledg re eipt of this Addendum and include wifih your bid. 05/05/20 (Signatures y MacPhee, Vice President Date Haskins ►nc. (Name of Firm) If you require additional information, please post a question on QidSync on-line or contact me using the above contact information. BOARD OF COUN"CY COMMISSIONERS COLLIER COUNTY, FLORIDA HICKORY ROAD WA'CER MAIN IMPROVEMENTS BID N0.20-T152 Full Name of Bidder HaSkinS InC. Main Business Place of Business 10956 10956 Bonita Springs, FL 34135 rise Avenue, Bonita FL 34135 Telephone No. 239-947-1$46 Fax No. 239'947-3857 State Contractor's License # CBC1260383 State of Florida Certificate of Authority Document Number L1606140000920 Federal Tax Identification Number 59�1$44470 DUNS # 106950637 CCR4 C35369 Cage Code 4460 To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA (hereinafter called the Owner) The undersigned, as Bidder declares that the only person or parties interested in this Bid as principals are those named herein, that this Bid is submitted without collusion with any other person, firm or corporation; that it has carefully examined the location of the proposed Work, the proposed form of Agreement and all other Contract Documents and Bonds, and the Contract Drawings and Specifications. ` id is accepted, Bidder will execute the Agreement included in the Bidding Bidder proposes, and agrees if this B achinery, tools, apparatus and other means of construction, including utility Documents, to provide all necessary m and transportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract, and to do all other things required of the Contractor by the Contract Documents, and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points, and in the case where further decimal points are inadvertently provided, rounding to two decimal points will be conducted by Procurement Services Division staff. Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement form attached to the Bidding Documents within ten (10) calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents. The bid security attached is to become the property of the Owner in the event the Agreement, Insurance Certificates and Bonds are not executed and delivered to Owner within the time above set al expense to the Owner, it being recognized that, since time forth, as liquidated damages, for the delay and addition is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period. In the event of such failure, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it fails to execute and deliver the Agreement, insurance Certificates, and Bonds as required hereunder. The ave to seek to characterize the Successful Bidder hereby expressly waives and relinquishes any right which it may h Construction Solicitation Doc rev 02-21-20 C O' above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely manner. Upon receipt ofthe sigtied and approved agreement and Purchase Order, ttie undersigned proposes to commence work at the site within five (5) calendar days from the commencement date stipulated in the written Notice to Proceed unless the Project Manager, in writing, subsequently notifies the Contractor of a modified (later) commencement date. The undersigned further agrees to substantially complete all work covered by this Bid within Two Hundred Forty (240) consecutive calendar days, computed by excluding the coin mencementdate and including the last day of such period, and to be fully completed to the point of final acceptance by the Owner within Thirty (30) consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. Acceptance and acknowledged ray an Authorize Agent Signature: Vice President Date: 05/05/2020 Gonsiruction Solicitation Doc rev 02-21-20 �; tit HICj%.VK x ROAD WATCR MAIN IMPROVEMENTS Name Greg Collier Ben Elwell Consfrucfion Soiicitaffon Doc rev 02-21-20 Bid No. 20-7752 Personnel Cate�ory Construction Superintendent Project Manager FORM 3 MATERIAL MANUFACTURERS HISFOR MUST' BE COMPLETED OR BID SHALL BE DEEMED NON -RESPONSIVE A11 Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this Bid specifications, including compliance with Florida Statute 255.20 to provide lumber, timber and other forest products produced and manufactured in the State of Florida as long as the price, fitness and quality are equal. Exceptions (when equals are acceptable) may be requested by completing the Material Manufacturer Lxecption List below. If an exception for a manufacturer and/or material is proposed and listed below and is not approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in the specification. Acceptance of this form does not constitute acceptance of material proposed on this list. Complete and sign section A ORB. Section A (Acceptance of all manufactures and materials in Bid specifications) Ott behalf of my firm, I confirm that «e �iill use all manufacturers and materials as specifically outlined in the Bid specifications. Com puny: .Signature: Section B (F,xception requested to Bid specifications manufachn•ers and materials) EXCEPTION MATERIAL I, 2. 3. �1. 5. Please insert additional jtages as necessary. Company: Signahu•e: Consfrucfiat Soiicifafion Doc rev 02-21-20 _05/05/20 EXCEPTION MANUFt\C:1'UIZF;R Date <nt� FORM 4 - LIST OF MAJOR SUBCONTRACTORS THIS LIST MUST BE COMPLETED ORBIDMAY BE DI.EMED Al The undersigned states that the following is a list of the proposed subcontactors for the major categories outlined in the requirements of the Bid specifications. The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the major categories listed herein are "qualified" (as defined in Ordinance 2017-08 and Section 15 of Instructions to Bidders) and meet all legal requirements applicable to and necessitated by the Contract Documents, including, but not limited to proper licenses, certifications, registrations and insurance coverage. The Owner reserves the right to disqualify tiny Bidder who includes non -compliant or non -qualified Subcontractors in its bid offer. Further, the Owner may direct the Successful Bidder to removc/h-cplace any Subcontractor, at no additional cost to Owner, which is found to be non -compliant with this requirement either before or after the issuance of the Award of Contract by Owner, (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award oi' Contract, and in accordance with the requirements of the Contract Documents, the Successful Bidder sliall identify ail Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified as noted above. Major Category of Work Subcontractor and Address 1. Electrical 2. Mechanical 3. Plumbing 4. Site Work rec ona ri : a ana ons rrucc 0 avmg sp a c onness n 5. Identify other subcontractors P,O Box 61646 1900 Seward Avenue, that represent more than 100/1' Fort Myers, FL 33906 Naples, FL 34109 of price or that affect the critical path of the schedule Sodding: Triple J Grassing Fort Myers, FL 33916 ConppanY: -._ Haskityls Signaturc: Construction Solicitation Doc rev 02-21-20 Date:. 05/05/20 attr#C_11oo I FORM 5 - STATEMENT OF ExPERIENC> OF BIDllER The Bidder is required to state below what work of similar magnitude completed within the last Iive (5} years is a judge of its experience, skill and business standing and of its ability to conduct the work as completely and as rapidly as required under• the terms of the Agreement. 2. 3. -- to c,c,t otvuer (project name) p (projject location) - (owner's address (project description) (owner's contact person) (project start/completion dates) (contract value) (p hone email (project name) (Project owner) (project. locatia�} -- (Owner's address) contact person) (tit e (project description) (pro•ject start/completion dates) (contract value} (project name) (project location) (project description) (project start/completion dates) (contractva►ne} Construction Solicitation Dor, rev 02-29-20 (phone) (project owner) (Owner's address) (email) _._. (owner's contac# person) (phone) (email) (title) s ....... _. _.. ... ___ __.... Statement of Experience of Bidder PROJECT MANAGER/SUPERINTENDENT REQUIRED OWNER 'S CONTACT DESIGNING ARCHITECT/ DESCRIPTION OF CONTRACT TITLE & LOCATION HASKINS, INC. CONTRACT CONTRACT COMPLETION COMPLETIO INFO ENGINEER AND ADDRESS THE WORK PRIME SUB PRICE DATE DATE CONTACT INFO N DATE 7/1/2019 D.R. Horton, Inc. -SWFL Avalon Engineering Complete Site The Village of Entrada X 3,200,000.00 7/1/18 In progress Mr. lames M. Ratz 2503 Del Prado Blvd Development D.R. Horton, Inc. - SWFL 10541 Ben C. Pratt Six Mile Cypress Pkwy Phase 2A & 2B Suite 200 Coral, FL 10541 Ben C. Pratt Six Mile Cypress Pkwy Suite 100 Cape Fort Myers, Florida 33966 Cape Coral, FL 33904 Suite 100 239-573-2077 Fort Myers, Florida 33966 239-225-2610 239-225-2610 11/1/2018 D.R. Horton, Inc. -SWFL Johnson Engineering Complete Site Magnolia Landing X $7,000,000.00 10/16/2017 In progress Mr. James M. Ratz Development D.R. Horton, Inc. -SWFL 10541 Ben C. Pratt Six Mile Cypress Pkwy Fort Johnson Street North Fort Myers, FL Suite 100 Fort Myers, FL 33901 10541 Ben C Pratt Six Mile Cypress Pkwy Fort Myers, Florida 33966 239-334-OD46 Suite 100 Fort Myers, Florida 33966 239-225-2610 239-225-2610 12/7/2017 Amy Hofschneider Johnson Engineering Drainage Installation Green Meadows WTP X $ 2,990,328.32 12/7/2015 In progress Josh Petro 2122 Johnson Street Utility Installation Ganey Companies, Inc. Lee County BOCC and Well Field Expansion PO Box 1550 Road Construction 370 East Crown Point Road PO Box 398 Fort Myers, FL 33902-0398 Fort Myers, FL 33902-1550 Lake Excavation Winter Garden, FL 34787 239-533-2111 239-334-0046 321-221-2835 7/31/2018 Peace River Manasota Regional Water Mr. Erik Howard, P.E., P.S.M. Pond Exzcava" on 2017-18 Storm Water Mgmt. X 700,000,00 1/4/18 7/25/2018 Mr. Tom Dobbs Embankment Peace River Manasota Regional Water Supply Authority PP Y tY Johnson Engineering Systems Improvements 9415 Town Center Parkway 2122 Johnson Street & Drainage Phase 1 Supply Authority 9415 Town Center Parkway Lakewood Ranch, FL 34202 Fort Myers, FL 33901 Arcadia, FL 941-316-1776 239.334-0046 Lakewood Ranch, FL 34202 941-316-1776 30" RW line Mr. David Ashman 8 1 2018 / / Mr. Don Woodruff RWA EngineeringInstall X 3,000,000.00 11/10/2017 7/15/2018 BSU-RO Bonita Springs Utilities, Inc. 6610 Willow Park Drive Suite 200 & conduits. CH2M Hill WELLFIELD 4350 West Cypress St, Suite. 600 11900 E. Terry St, Naples, FL 34109 P Large diameter Bonita Spr 7FL Tampa, FL 33160 Bonita Springs, FL 34135 239-597-0575 Directional drills, jack & bores 813-281-7747 239-992-0711 1/31/2018 SAME AS PROJECT Clay W. Rebol, P.E. Drainage Installation Venetian Pointe X $ 6,590,310.05 i/19/2D17 1/7/2018 Mr. Andrew Zuckerman Utility Installation Lynx Zuckerman at Naples, LLC MANAGER'S INFO Banks Engineering Fort Myers, FL Page 1 of 5 `It ''r'vu tu _.,-.�..., ;srlrz,, F ., 1 Statement of Experience of Bidder CONTRACT TITLE & LOCATION HASKINS, INC- CONTRACT CONTRACT COMPLETION PROJECT MANAGER/SUPERINTENDENT REQUIRED OWNER'S CONTACT DESIGNING ARCHITECT/ DESCRIPTION OF PRIME SUB PRICE DATE DATE CONTACT INFO COMPLETIO INFO ENGINEER AND ADDRESS THE WORK N DATE 6131 Lyons Road, Suite 200 4161 Tamiami Trail Road Construction Coconut Creek, FL 33073 Building 5, Unit 501 Pond Excavation 954-481-3700 Port Charlotte, FL 33952 941-625-1165 X $ 1,265,639.80 7/25/2017 7/6/2018 Mr, Keith Jennings 7/31/2019 Mr, Keith Jennings D. Brent Addison, P.E. Drainage Installation Bonita Exchange Bonita Exchange, LLC Bonita Exchange, LLC Grady Minor Utility Installation Bonita Springs, FL 9916 E. Harry, Suite 104 9916 E. Harry, Suite 104 3800 Via Del Rey Road Construction Wichita, Kansas 67207 Wichita, Kansas 67207 Bonita Springs, FL 34134 239-287-9189 239-287-9189 239-947-1144 FGCU Lake Front Development X $ 366,511,80 11/14/2016 11/14/2017 ROBBIE POWELL, PROJECT MANAGER 1 Yr FGCU Financing Corporation STUDIO PLUS, LLC Drainage Installation WRIGHT CONSTRUCTION GROUP, INC. 10501 FGCU Blvd. South Utility Installation 5811 YOUNQUIST ROAD Fort Myers, FL 33965-6565 Road Construction FT, MYERS, FL 33912 239-590-1130 Pond Excavation 239-481-5000 Memorial Pathway on X $ 2,341,D44.22 7/15/2016 7/3/2017 SHANNON BASSETT, PROJECT MANAGER 7/3/2017 SAME AS PROJECT DANIEL C. HALL UTILITY INSTALLATION COLLIER COUNTY, GROWTH MNGMNT DIV, MANAGER'S INFO CC TRANSPORTATION Road Construction Vanderbilt Drive PROCUREMENT SERVICES DIVISION ENGINEERING DIVISION 3339 TAMIAMI TRAIL EAST NAPLES FL, 34112 239-252-8407 Collier Blvd. x $ 60495,591.71 3/23/2015 5/9/2017 Dennis Breuer, PROJECT MANAGER 5/9/2017 Kevin Dugan, PM Drainage Installation Green to Golden Gate Community Asphalt Corporation COLLIER COUNTY Utility Installation 14005 NW 186th Street PUBLIC UTILITIES Road Construction Capacity Improvements Hialeah, FL 33018 3339 TAMIAMI TRAIL EAST, STE 3 Pond Excavation 305-829-0700 - NAPLES FL, 34112 239-252-6279 x $ 51023,000,00 3/15/2015 4/4/2017 Ryland Thompson, Project Manger 4/4/2017 Continental Properties Clay Rebol Pond Excavation Six Mile Crossing Albertelli Construcion W134 N8675 Executive Pkway Banks Engineering Utility Installation Phase I & 11 10751 Deerwood Park Blvd. Ste 105 Menomonee Falls, WI 53051 12653 SW County Rd. 769 Construct Roads Jacksonville, FL 32256 Lake Suzy, FL 34269 SR 90 (US 41) SR/CR 951 X $ 4,680,510.84 1/19/2014 11/30/2016 Dennis Breuer, PROJECT MANAGER 11/30/2016 Kevin Dugan, PM Jon Ahlschwede Drainage Installation I Community Asphalt Corporation COLLIER COUNTY Stanley Consultants and Utility Relocation and SR 951311 Improvements Page 2 of 5 - � % rs -. ..�' Vi 'se Fri . ;".p s tt Ala r Statement of Experience of Bidder CONTRACTTITLE & LOCATION HASKINS, INC. CONTRACT CONTRACT IIililETION PROJECT MANAGER/SUPERINTENDENT COMPLETIO PRIME SUB PRICE DATE DATE CONTACT INFO N DATE Contract No.: 13-6134 FAP# N/A Collier County Natura at Bonita Fairways Marco Island Marriot Utilites Installation Pelican's Nest Reclaim Water Main Fountain Lakes Force Main PH II SR739 (US 41 BUSINESS) NFM SWAN LAKE DR. TO N. CLEVELAND N. FORT MYERS, FL UPGRADES TO In WATER SITES PRIORITY GROUP # 3 P5312.21 REHABILITATION 14005 NW 186th Street Hialeah, FL 33018 OWNER'S CONTACT DESIGNING ARCHITECT/ DESCRIPTION OF INFO ENGINEER AND ADDRESS THE WORK >UBLIC UTILITIES 1641 Worthington Rd., Suite 400 3339 TAMIAMI TRAIL EAST, STE 3 West Palm Beach, FL 33409 NAPLES FL, 34112 561-584-8760 305-829-8772 Utilities Installation X $ 2,338,943.30 10/28/2014 7/31/2016 Home Dynamics Bonita Fairways, LLC 10/15/2015 Home Dynamics Bonita Fairways, LLC Q. Grady Minor & Site Work 4755 Technology Way, Suite 210 3800 Via del Rey 4755 Technology Way, Suite 210 Boca Raton, FL 33431 Bonita Springs, FL 34135 Boca Raton, FL 33431 T: 561-869-1800 239.947-1144 T: 561-869-1800 F: 561-869-1820 F: 561-869-1820 Sanitary Sewer Install 8/30/2015 Marco Island Marriot Resort & Spa HKS x $ 1,055,400.00 5/5/2015 8/5/2015 William Utsler, Project Manager Aqua Thermal Line Install Heritage Builders 400 S. Collier Blvd. Naples, FL Drainage Install 8/30/2015 Pelican Nest Golf Club Frank Feeney Reclaim Water Main x $ 1,027,475.00 6/8/2015 8/1/2015 Jason Zimmerman, Nest Golf Director of Grounds Installation 4450 Pelicans Nest Drive Q. Grady Minor Pelican's Nest Golf Club Bonita Springs FL 34135 3900 Bia Del Rey 239-949-5664 Bonita Springs, FL Steven Martin Pump Station Rehab 9/1/2015 Bonita Springs Utilities x $ 942,311.00 2/15/2015 7/14/2015 Gary Pflieger, Project Manager 11860 East Terry St. Agnoli, Barber & Brundage Force Main Installation Bonita Springs Utilities Tani Pond Bonita Springs, FL 34135 7400 TamTrail N, Ste 200 239-992-0711 Naples, FL 34108 BRIAN ROSE WATER MAIN X $ 10265,591.63 9/9/2013 11/5/2014 ROBBIE POWELL, PROJECT MANAGER 1/30/2015 FLORIDA DEPARTMENT TETRA TECH, INC. INSTALLATION WRIGHT CONSTRUCTION GROUP, INC. OF TRANSPORTATION 801 N. BROADWAY AVE. 10600 CHEVROLET WAY, #300 5811 YOUNQUIST ROAD BARTOW, FL 33830 ESTERO, FL 33928 FT, MYERS, FL 33912 239-390-1467 239-481-5000 UPGRADES TO IQ SAME AS PROJECT FRANK FEENEY, P.E. X $ 405,000.00 2/4/2013 3/5/2015 AARON CROMER, PROJECT MANAGER HOLE MONTES, INC. WATER SITES COLLIER COUNTY, PUBLIC UTILITIES MANAGER'S INFO 950 ENCORE WAY 3339 TAMIAMI TRAIL EAST, STE 3 NAPLES, FL 34110 NAPLES FL, 34112 239-254-2061 239-252.4285 TYLER WAINRIGHT, E.I. PUMP STATION X $ 2560130,00 7/9/2013 7/23/2014 ZAMIRA DELTORO, PROJECT MANAGER 365 DAYS SAME AS PROJECT TETRA TECH, INC. REHABILITATION COLLIER COUNTY MANAGER'S INFO 10600 CHEVROLET WAY, #300 PUBLIC UTIUTIES ESTERO, FL 33928 3339 TAMIAMI TRAIL EAST, STE 3 r'i"� Page 3 of 5 r R "- 14 ffi',23,,�5: Statement 01 Experience of Bidder CONTRACT TITLE & LOCATION HASKINSIINC,j CONTRACT CONTRACT COMPLETION PROJECT MANAGER/SUPERINTENDENT REQUIRED OWNER'S CONTACT DESIGNING ARCHITECT/ DESCRIPTION OF COMPLETIO INFO ENGINEER AND ADDRESS THE WORK PRIME SUB PRICE DATE DATE CONTACTINFO NDATE NAPLES FL, 34112 239-390-1467 239-252-6279 IQ/REUSE VALVE REPLACEMENT X $ 355,500.00 7/22/2013 4/21/2014 WAYNE M. KARLOVICH, PROJECT MANAGER 365 Days SAME AS PROJECT VALVE COLLIER COUNTY PUBLIC UTILITIES MANAGER'S INFO HOLE MONTES, INC. REPLACEMENT 3339 TAMIAMI TRAIL EAST, STE 3 950 ENCORE WAY NAPLES FL, 34112 NAPLES, FL 34110 2 239-252-5372 39-254-2000 DONAX WATER X $ 168,955,00 4/16/2013 3/20/2014 KEITH WILLIAMS, PUBLIC WORKS DIRECTOR 60 DAYS SAME AS PROJECT TYLER WAINRIGHT, E.I. INSTALL PERMANENT RECLAMATION FACILITY CITY OF SANIBEL ISLAND MANAGER'S INFO TETRA TECH, INC. BYPASS AND NEW FLOW HEADWORKS BYPASS 800 DUNLOP ROAD 10600 CHEVROLET WAY, #300 METERS IN AN SANIBEL, FL SANIBEL, FL 33957 ESTERO, FL 33928 UNDERGROUND VAULT, 239-390.1467 239-472-4555 US 41 BUSINESS X $ 798,550.00 7/24/2013 Apr-14 JESSICA MUNOZ, PROJECT MANAGER 4/24/2014 SAME AS PROJECT FCHRISTOPHERROSENBOOMOSENBOOM WATER MAIN (SR739) WATER LEE COUNTY UTILITIES MANAGER'S INFO INSTALLATION MAIN RELOCATION 1500 MONROE STREET S DRIVE, # 106 FORT MYERS, FL 33901 33913 239-533-8155 REGENT PARK X $ 474*026,50 8/1/2013 Dec-13 ZAMIRA DEL TORO, PROJECT MANAGER 12/19/2013 SAME AS PROJECT DARED R. BROWN, P.E. SANITARY SEWER SANITARY SEWER COLLIER COUNTY PUBLIC UTILITIES MANAGER'S INFO JOHNSON ENGINEERING, INC. REPLACEMENT REPLACEMENT 3339 TAMIAMI TRAIL EAST, STE 3 2350 STANFORD COURT NAPLES FL, 34112 NAPLES, FL 34112 239-280-4321 239-252-6279 Natalie Urick ABANDON AND ARV REPLACEMENT PROGRAM X $ 10048,470.00 10/18/2012 Jul-13 CORINE TRTAN, PROJECT MANAGER 7/10/2013 SAME AS PROJECT COLLIER COUNTY MANAGER'S INFO AECOM INSTALL NEW PUBLIC UTILITIES 150 N Orange Ave ABOVE GROUND ARVS 3339 TAMIAMI TRAIL EAST, STE 3 Orlando, FL 23801 NAPLES FL, 34112 407-843-6552 239.252-4233 ISLE OF CAPRI X $ 1,161,9Z2,00 Oct]] OCi. 2011 fDIANA CUERI, PMP10/22/2011 SAME AS PROJECTDavid Schmitt WATER MAIN PHASE II LLIER COUNTY MANAGER'S INFO Q. Grady Minor REPLACEMENT Page 4 of 5 CONTRACT TITLE &LOCATION 11/15/10- 9/30/2011 LELY CANAL 4/12/10 - 11/24/10 SONITA BEACH RD FORCEMAIN UPGRADE BONITA BEACH RD. SECTION 4 & S COLLIER BIVD y 4 �'�� '�,.L � �vi..�.�,td.. L•,..r. BlziJts`=..�, ..�.., r`�.. azbi � Statement of Experience of Bidder AREQUIRED SKINS, INC. CONTRACT CONTRACT COMPLETION PROJECT MANAGER/SUPERINTENDENT COMPLETIO PRIME SUB PRICE DATE DATE CONTACT INFO N DATE 4370 MERCANTILE AVENUE NAPLES, FL 34104 X ( � $ 896,000.OD' Dec-10 X � I $ SOO,D00.00 � Jan -SO X � $ 785,000.00 X � $ 1,600,000.00 DEC. 2010 R. SHANE COX, P.E. COLLIER COUNTY TRANSPORTATION ENGINEERING DEPT 3301 TAMIAMI TRAIL EAST NAPLES FL, 34112 2010 MICHAEL LIGGINS, DIRECTOR OF ENGINEERING DEPT BONITA SPRINGS UTIUTIES, INC. PO BOX 2368 BONITA SPRINGS, FL 34133 2010 DALE CARNES NNESS INC. NBOX 9140 PLES, FL 34101239-597-6221 DEC. 2009 I.R. RESTING BETTER ROADS, INC. PO BOX 9979 NAPLES. FL 33941 Page 5 of 5 1"-. x; 2 i'. j7•�ii`.eJ� OWNER'S CONTACT INFO AS PROJECT ,GER'S INFO AS PROJECT ,GER'S INFO DESIGNING ARCHITECT/ ENGINEER AND ADDRESS )0 Via del Rey iita Springs, FL 34135 DESCRIPTION OF THE WORK EXCAVATION, BOX CULVERT & WATER CO NTROL STRUCTURES 16" FORCEMAIN INSTALLATION DRAINAGE INSTALLATION FORCEMAIN RELOCATION & DRAINAGE INSTALLATION 5, (project name) (project location) FORM 5 STATEMENT OF EXPERIENCE OF BIDDER (project owner) (Orwrer's address) (project description) (Owner's contact person) (project completion date) (contract value) (phone) (project name) (project location) (project owner) (Owner's ad<h•ess) (email) (project description} (Owner's contact person) {project completion date) (contract value) (phone) (email) (project name) (project location) (project owucr) (Owner's address) (project description) (Owner's contact person) (project completion date) (contract value) (phone) (email) Company: Signature; President Construction Solicitation Doc rev 02-2.1-20 (fitle) Date: 05/05/20 FORM b -TRENCH SArGTI' ACT Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (9U-9G, Lavvs of Florida) effective October 1, 1940. The Bidder ftn•ther identifies the cost to he summtu•ized below: ' Unit Unit Extended Cost Trench Safety Units of Cost Measure Measure uantit (Dascription� � SY 500 $1.00 $500.00 � Genereal Sloping LF ______---.------- LF 400 $2.00 $800.00 2. Trench Box-----�-----�--- 3. 4. J. To'rAL S � ,300.00 Failure to complete the above may result in the Bid being declared non -responsive. C�mpauy: Has Signature:. ��ce President Construction Solicifation Doc rev 02-21-20 Datei 05I05/20 • T'OTZM.7 - KNOW 11T I, ivt1.II BY THESE PRFsSEXJ'S, that we i�c1�k1C1�, {11C;. (herein alter called the Principal) and H. \ Western �(froty CA (herein called the Surety), a c orpora Vition c ar ere( and _ _ _ exi.,tulg under the laws of the State of Smith Dakota with its principal offices in the city of _; hkago�______ and authorized to do business tit the State oi' .. are field and firmly bound unto the ,1�1C11'lCt� Co{{Ier CO1,lMy QOard Of CoUI* C0111MISsiOne1 s (ieranl rt r culled the t T%vi �ri_ in thn full and just sent of F VE pel0eMt Of alFFl-)"1 f.111t bid tlulLlrti (S 5% } f,ocxl anetlawfitl money of the IJnttuf "totes of America, to be paid upon demand of the Owner, to which payment well and truly to lnz oracle, the Principal and the Surety bind themselves, their heirs, and executors, adnl iriisfrators, and assigns, jointly and severally and Ci-mly by these presents. \ulnercas, the Principal is about. to submit, nr has submitted to the (huller, a Bid for fiu•nishing all labor, materials, equipment and incidentals necessary to furnish, install, and fully complete: the Work an the Project known as Blti iVo, 20-7752, I-'tJCB' ORY ROAD 'VVATE,R MATH IMPROVE ifte TS. NU\j�, t'JIF�,RI;FORT, if the Owner shall accept the Bid aP the f>RIhICIPAL and. t}le PI:TNCIf'Ah shall en4;1,r itlto the require?d t\11Ircomen( whit the Owner and within tell days after the date of a written Notice of Award in accordance with they terms (ni'such t3id, and give such bond or bonds in an amount of 100°'o the total Contract- Amount as specified in the t3idding T)octuuents or Contract Documents with good anti sufficient surely for the CaiUlftd performance of the Agreement and For the prompt payment of labor, materials runt supplies furnished in the prosecution thereof or, in the event of the failure of (lie PRINCIPAL to eater a oo such Agreement or to give, such bond or bonds, and deliver to Owner file regtured certificates of insurance, if the PRINCIPAL shall pay to the OBLIGfa (lie Ci led urn ;a1'ti wX T _. _noted shave as liquidated damages, and notas a penalty, as provided in the. Bidding f rtwili n�nts, tile:)) tilts 0171if Lion shall be null and void, otherwise to remain in full farce and effect. IDl 'I'Ca>TTt`,L(!`,I\' "fhereol; dne Principal and Surety have: caused these presents to bt: duly signed and sealed -this. Jth clay of IVIR.... _— .... F._• 20 20 .. BI' �t1 �'(7(nntel'tilgrled IV��i Appointed Producing Agent for Corn��n Paul A. Locascio, Altcrneyin•Fart & 1=L Residt3nt A�enl Principal, (Seal) S7rretIF OF y fStitlrIF IF t POWER OF ATTORNEY APPOINTING INDIVEO e1L ATTORNEY -IN -I AST Know All Men By These presents, 11,11 WESTERN SiIRETY COMPANY. a South Daltola c,orpomti(in, is a chdy organized atnd existing corporation having its principal office in Hit City of Sioux Falls, and Stalc of SonUt DAkola, and dial it does by virtue of die signature and seal herein affixed hereby make, constitute and appoint L,Dale Waldorff, Benjamin n Prench, Pamela L. Janatan, Paul Loeascio, iC. V6'ayne Walkeal, Rebekah G Wolf, Individually oL Fort LValtell Beach, pL, its tote and lawfttl Auemey(s)•in-Fact rviUt full power arnd authority htceby conferred to sign, seal and execute for and tln Its behalfbonds, undertakings and other obligatory instruments of similar nature - Irt Utnlitaiited �fal:o>isnta - end to bind it thereby as Nlly and to the same extent as if such instruments were signed by a duly authorized o�cer of Ule corpora►ian and ai{ the acts of said Attorney, pursuant to Uic authority hertby given, are bercby ratified and confimrcd. Ttds Pmver of Auomty is made and executed pursuant to AnJ by auUrority of the By -Law printed on the reverse hereof, duty adopted, as indicated, Uy the shareholders of the corporation. In Witrness Whereof, bVE5'I'CRN SUfiETY C01vfPA1JY has r:aused [hest presents to be Sigtted by its Vicc President and its corporate sra! to be hereto affixed on this 7Un day of April, 2020. WESTERN SURETY COMPANY �` ate--. cow Cr % Paul T. Sruf]at, Vice Presi+tcnr State of South Dakota � ss County of Mintuehaha On Utis Jth day of April, 2020, before mt personally came Paul T. Bmflal, tome known, who, bring by Irie dttiy s<vom, did depnse a»d say: Ural he resides ut Ure City of Sioux Fails, state of South Dakota; that Irc is Ute Vicc President of 6VESTETtN SURETY CO1vIPA?IY described ht andtvhich executed the above inshutncnt; that he knows the seal of said corporation; that the seal atiixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that Ire signed his name thereto pursurnt to We authority, and acknowledges same to be the act and deed of said corporation. My commission expires if MOHR JuuC 23, 2021__ ri rum+a,Kou , 1. �hihr, Notary Public CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hueby etiiify Ojai flit Power of Attorney hereinabove set fort]) is stilt in force, and further cerlO 1iig1 the By -Law of the corporation printed on U)e reverse hereof is still in force. In testimony whereof f have hereunto subscribed my name and difeceiiihe sea] of,ttit'kinid +:tuperatimn this5th day "May, 2020. r" WESTERN SURETY COMPANY . , � 1 j •r _ _ ._..... .,... 1.. Nclsmn, Assistant Secretary WWI rorot e4280-7-201Zf( I .r : ;i Go to www rna;ureplocom > Owner / Obiigee Services > Validate pond Coverage, if you want to verify bond authenticity, ADOPTED BY THE SHAREHOLDERS OP WESTERN SURETY COMP�INY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. A11 bonds, policies, undertakings, Powers of Attorney, or outer obligations of the corporation shall be executed in the corpomte name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize, The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer ntay appoint Attorneys in Pact or agents who shall have authority to issue bonds, Policies, or walcrtalcings ut the name of the Cmnperty, The corporate seal is not necessary for the validity of any bonds, policies, wulertakinW, Powers of Attorney or other obligations of the corporation. The signature of arty suds officer and. the corporate seal may be printed by facsimile. Tfie Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in FORM 8 of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. ign The County and the Vendor waive against each other and the County separate Vendors, Contractors, Des Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Vendor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. ity Collier County shall be responsible for purchasing and maintaining its own liabilinsurance. Certificates issued as a result of the award of this solicitation must identify "For any and ali work performed on behalf of Collier County", or, the specific solicitation number and title. The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in FORM 8 with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. if Vendor has any self - insured retentions or deductibles under any of the below listed minimum required coverage, Vendor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self insured retentions or deductibles will be Vendor's sole responsibility. Coverageos shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Vendor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non -renewal on the part of the insurance carrier or the Vendor. The Vendor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non - renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder, Vendor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverage,( required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverageLss) and charge the Vendor for such cover•age(s) purchased. If Vendor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Vendor under this Agreement or any other shall be under no obligation to purchase such insurance, nor agreement between the County and Vendor. The County shall it be responsible for the coveragej� purchased or the insurance company or companies used. The decision of ll in no way be construed to be a waiver of any of its rights the County to purchase such insurance coverages sha under the Contract Documents. If the initial or any subsequently issued Certificate of insurance expires prior to tine completion of the scope of work, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. Collier County N 101'Ida Insurance and Bonding Requirements Ins►irance / Build Type Requires .,units 1, ® Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory limits and Requirements Evidence of Workers" Compensation coverage or a Certificate of Elxemption issued by the State of Florida is require<!. L'•artities that are formed as Salo Proprietorships shall not be required to provide :rproot of exemption. An application for exemption Cali be obtained online at I►ttus:flahps fldls.cour�boccaennpt_' 2. Employer's Liability S^_ 1,000,000_ single iiurit per occurrence 3, Commercial General Bodily injury and Property Damage Liability (Occurrence I,000,000_singie limit per occurrence, $2,00000 aggregate for Bodily Injury Form) patterned after the $_ Liability and Property Damage Liability. This shall include Premises and Operations; current ISO form L independent Contractors; Products and Completed Operations and Contractual Liability* xtent permitted by Florida law, the Contractor/Vendor shall ®Indemnification Pro the maximum e defend, indemnify and hold harmless Collier County, its officers and employees from 4• any and all liabilities, damages, losses and costs, including, but not Limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the contractor/ Vendor or anyone employed or utilized by the Contractor/Vendor in the performance of this Agreement. 5, � Automobile Liability O()wued% Ti 000 red; O curie Ie;lnclBodil Injury & Property Damage, wned/ (, ® Other insurance noted: as ❑ Watercraft $ Per Occurrence (-j United States Longshoreman's and Harborworker's Act cov ❑ Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. $ Per. OCCnr'reneC ❑ Aircraft Liability Coverage shall be carried in limits of not less than $5,000,000 each occurrence if applicable to $le completion of the Serviunder this Agreement. ces Per Occurrence (� Pollution ❑ Li $ 1,000,000 Per Occurrence 0 ❑ Project Professional L,iabitity ❑ Per claim $ _ Per Occurrence Per Occurrence Per Occurrence $ __ 1'er Ocau•renee 7 E3 9 fit Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of tine cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. ®is of $200,(100, bonds shall be submitted with the executed Performance and For projects in exce Pcontract by Proposers receiving award, and written for 100% of the Contract award ayment Bonds amount, the cost borne by the Proposer receiving as award. The Performance and horized to do business in the Payment Bonds shall be underwritten by a surety aut State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, Published by A.M. Best CoutpanY, Inc, of 75 Fulton Street, New York, New York 10038. ®Vendor shall ensure that all subcontractors connPly with the same insurance requirements that he is required to meet. The same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. ® Collier County must be named as "ADDITIONAL INSURED" or~ the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect policy any other insurance maintained by, or available for the benefit of, the Additional Insured and the Vendor's policy shall be endorsed accordingly. ® lier County Board of County Commissioners, OR, Board of The Certificate Holder shall be named as Col OR Collier County Government, OR Collier County. The Certificates County Commissioners in Collier County, of lnsurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County, 12• m On all certificates, the Certificate Holder must read: Collier County Board of Commissroners, 3295 Tamiami Trail East, Naples, Fl. 34112 136 ®Thirty (30) Days Cancellation Notice required. prOJOCtS ere t is 14. Collier County Shall nrocutshallrlbetentlorsedintain rto Coveers ll tile interests rCounty as well �as the rC"ontractar necessary, Such 6 Prernniums shall be billed to the project anal the Contractor shall not include Builders Risk premitmns in its project proposal or project billings. All questions regarding Builder's Risk insurance will be addressed by the Collier County Risk Management Division. 4/1/20 - CC Vendor's lnsurance Acceptance By submission of the bid Vendor accepts and understands the datsaof the awat•d of tfus solicitation cThenh>Srt�ance the evidence of insurability may be required within five months from the date of award. y. submitted mast provide coverage for a minimum of six (() m t7 11%e ° 014l 1,Y 1 ct-ninistrative Sepiiccs Department Proci�ret7?eni Sn!',i�y> [3i�i�i�n FORM 9 - ConrFt.tc, r ot�• INTrRrs�r Art�ro�wtT Ttic Vendor certifies that, to the best of its knowledge and belief, the past and cturent work on any Copier County project affiliated with this solicitation does not pose an organizational conflict as described by one of tine three categories. below: Biased ground rules —'file firm has not set the "ground rules" for affiliated past or current Collier County project identified above (e.g., writing a procurement's statement of work, specifications, or performing systems engineering and technical direction for tine procurement) which appears to skew the competition in favor of my firm. Impaired objectivity -The firm has not performed work on an affiliated past or current Collier County project identified above to evaluate proposals / past performance of itself on• a competitor, which calls into question the contractor's ability to render impartial advice to the government. Unequal access to information —The firm has not had access to nonpublic information as part of its Ierformance of a Collier County project identified above which may have provided the contractor (or an affiHate) with an unfi fid competitive advantage in current or firture solicitations and contracts. Lt acidi[ion to this signed affidavit, the contractor/vendor• must provide the following: I . All documents produced as a result of the work completed in the past or currently being worked on for the abovc- mentioned project; and, 2. Indicate if the information produced was obtained as a matter of public record (in the "sunshine") or through non public (not in the "sunshine") conversation (s), rneeting(s), documents) and/or other means. Failure to disclose all material or having an organizational conflict in one or more of the three categories above be identified, may result in the disqualification for future solicitations all with the above referenced project(s)0 By the signature below, the Firm (employees, officers and/or agents) certifies, and hereby discloses, that, to the best of their knowledge and belief, all relevant facts concerning past, present, or currently planned interest or activity (financial, contractual, organizational, or otherwise) which relates to the project identified above has been fully disclosed and does not pose an organizational conflict. Haskins4ncf� Company Name t ` t" �" Signature cPhe_ e, Vice President 1 Print Name and 'Title State of _ Florida County of—_- ,Lee "I'he foregoing instrument was aelcnowledged before me by means of � physical presence or ❑online notarization, this 5th day of May ____ (month), 2020 (year), by Ryan Mai✓ `,tee _ (name of person acknowledging). 1. Id (Signs I. 1' Notary Public - State of Florida) Sol F'al pakdeediskul (Print, TC_ontmissioned Name of Notary Public) Personally Known OR Produced Identification :;QZV�' vv;;., SOLPANPAKDEEDiSKUI personally known Q Notary Public. State of Floridae= Commission H GG 59788 Type of Identification Produced 4f,V my Comm. Expires Jan M1, 2021 Adrnini �r�iivb 5e�ti c.e� Depaft� y��{����i Proevrem,t�t Se:rvi.;es Clivis�e�� t�'ORI�1 10 - Yi:NDOR DLCLARt�TION S'CA1'1;NIisNT BOARD OF COUNTY COMMISSIONEKS Collier County Government Complex Naples, Florida 34112 Dear Commissioners: The undersigned, as Vendor declares that this response is made 4vithout connection or arrangement with any other person and this proposal is in every respect fair and wade in good faith, without collusion or fraud. The Vendor hereby declares the instructions, purchase order terms and conditions, requirements, and specifications/scope of work of this solicitation have been fully examined and accepted. The Vendor agrees, if this solicitation submittal is accepted, to execute a Collier County document for the purpose of establishing a formal contractual relationship between the firm and Collier County, for the performance of all requirements to which the solicitation pertains. The Vendor states that the submitted is based upon the documents listed by the above referenced Solicitation. Further, the vendor agrees that if awarded a contract for these goods and/or services, the vendor will not be eligible to compete, subunit a proposal, be awarded, or perform as a sub - vendor for any future associated with work that is a result of this awarded contract. iN WITNESS WHEREOF, WE have hereunto subscribed our names on this 5th clay of Maw, 2o201n the County of Lee in the state of_ Florida Firm's Legal Name: Address: Z City, State, ip Code: I� lorida Certificate of Authority Document Number Federal Tax Ideutification Number *CCR # or CAGE Code Only if Grant Funded Telephone: Email: Signature Uy: ('Typed and written) Title: Haskins Inc. i nc)S6 Enterprise Avenue 239-947-1846 Send payments to: (required if different from above) Contact name: Title: Address: City, State, ZTP Telephone: Email: Office servicing Collier County to place orders (required if different from above) Contact name; Title; Address: City, State, ZIP Telephone; Email: Secondary Contact for this Solicitation: Email• Phone: Additional Contact Information Haskins Inc. Company name used as payee Ryan MgcPhee Vice President 10956 Enter rise Avenue Bonita S ri Is FL 34135 23M47�1846 rmacphee@haskinsinc.net Mabel Lago mla o haskinsinc.net 239-947-1PAR Adminisiratnra Senticcs Qepa+t,77ent Fro+a+rem+>nt Seivir,<s Clivisfc�t� rORM 11 - Ihi\•iIGRA'I'ION t1TT'IDAVI'i' CGRTtP'tt:ATION This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with formal solicitation submittals. Further, Vendors are required to be enrolled in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Vendor's bid. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully eXecuted L:-Verify Memorandum of Understanding for the company vvhich will be produced at the time of the submission of the Vendor's M bid or with in five (5) day of the County's Notice of Recommend Award. FAILURE TO li�LCU'1`L; ttii� f�.rr�u�v�A v.�r�rii�.tx,.,+ PROPOSAL/BID MAY DEEM THE VENDOR NON -RESPONSIVE. Collier County will not intentionally avvard County contracts to any Vendor vvho knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 tJ,S.C. Section 1324 a(e) Section 274A(e) of the hnm igration and Nationality Act ("INA" ). Cotlicr County may consider the employment by any Vendor of unauthorized aliens a violation of Section 274A (e) of the INA, Such Violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be grounds for unilateral termination of the contract by Collier County. Vendor attests that they are folly compliant with all applicable immigration laws (specifically to the 1986 Immigration tict and subsequent Amendment(s)) and agrees to comply with the provisions of the Ivlemorandurn of Understanding with E-Verify and to provide proof of enrollment in The Employment Eligibility Verification System (E-Verify), operated by the Department of Homeland Security in partnership with the Social Security Administration at the time of submission of the Vendor's bid. tNNatins Inc. Company Name —'-' tom- - Signature l2yat �MacPhee, Vice President 4 Print Name and Title State of Florida County of Lee„ • The Foregoing instr•iunent was acknowledged before me by means of R physical presence or ❑ online notarization, this 5th_ day of (mouth), 2020 (year), by Ryan MacPhee (name of person acknowledging). • Personally Knovvn OK Produced Identification Personally known Type of Identification Produced 5ignattu•e tl �•' otary Public -State of Florida) Sol P�np i<deediskul (Print, Type, or Stamp Commissioned Name of Notary Public) �i�YD�e^•• SOLPANPAKOEEDISKUL t�' 4ai Notary PubUc • State of Florida ':���" Commisston k GG 59788 '�°Fo My Comm. Expires Jan 4, 2021 IMPORTANT: Please read carefully, sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: 1 • The Bid has been signed. 2. The Bid prices offered have been reviewed. 3. The price extensions and totals have been checked. 4. Bid Schedule has been completed and attached, 5. Any required drawings, descriptive literature, etc. have been included, 6, Any delivery information required is included. 7. The following on-line standard documents have been reviewed and accepted in BidSync: a. Construction bid instructions form b. Construction services agreement c. Purchase order terms and conditions 8. All of the following bid forms have been completed and signed: a. Bid Form (Form 1) b. Contractors ley Personnel (Form 2) a Material Manufacturers (Form 3) It. List of Major Subcontractors (Form 4) e. Statement of Experience (Form 5) f, Trench Safety Act (Form 6) g. Bid Bond Fortin (Form 7) h, Insurance and Bonding Requirements (Form 8) i. Conflict of interest Affidavit (Form 9) j. Vendor Declaration Statement (Form 10) k. Immigration Law Affidavit Certification (Form 11) MUST be signed and attached with your submittal or you MAY be DEEMED NON -RESPONSIVE 1. Signed Grants Provisions Package (if applicable) MUST be utilized for each required reference and included with your submittal, or you MAY be DEEMED NON -RESPONSIVE 9. Copies of required information have been attached a. Business tax Receipt (Collier County Businesses Only) b. Company's ENerify profile page or memorandum of understanding c. Certificate of Authority to Conduct Business in State of Florida (sunbiz.org) d, Any required professional licenses — valid and current (myfloridalicense.com) (ie: General Contractors license, Underground Utility and Excavation, Builders, Trade Contractors, etc., as applicable, requested and/or required.) 10. If required, the amount of Bid bond has been checked, and the Bid bond or cashier's check has been submitted. 11. Any addenda have been signed and acknowledgement form attached and included, or you MAY be DEEMED NON -RESPONSIVE. 12. The Bid will be uploaded in time to be received no later than the specified ouenina date and time, otherwise the Bid cannot be considered. Mabel Lager Haskins Inc. Ji MLLzC04i5 EVerify P %T:.Ts QUICK LINKS elA rVerifyEVerffy I rMessage Center 7 � l opon%cosesl to be Clasecl �ah_�x r» ti h•la^.�, a �,r,:l- '�4s.�eens ':^ Pe, .,,j t r :ale RICK SCOTT, GOVERNOR JONATHAN ZACHEM, SECRETARY STATE OF FLORIDA DEPARTMENT OF BUSINESS AN-D PROFESSIONAL REGULATION CONSTRU rN.1S CERTIEIED;UNDER THE PROVISIONS OF CHAN 1 tK'4ti` EXPIRATCON DATE:..: AUGUST 31, 2020 Always verify licenses online at MyFloridaLicense.com Do not alter this document in any form. ther than the licensee This is your license. It is unlawful for anyone oto use this document. RICK SCOTT, GOVERNOR CONSTRU THE UNDERGROUND PROVI JONATHAN ZACHEM,sECRETAKY STATE OF FLORIDA ERTIFIED UNDER THE EXPIRATItON DATE:_.`AUGUST 31, 2020 Always verify licenses online at MyFloridaLicense.com Do not alter this document in any form. This is your license. It is unlawful 4or anyone other than the licensee to use this document. RICK SCOTT, GOVERNOR STATE OF FLORIDA n�aoRTMFNT OF RUSINESS�AND PROFESSIONAL REGULATION In n nn LICENSE NUMBER: CUC1224599 EXPIRATION DATE:._ AUGUST 31, 2020 Always verify licenses online at MyFloridaLicense.com Do not alter this document in any form. This is your license. It is unlawful for anyone other than the licensee to use this document. 1 Jimmy PalroNs C:IiIF F FINANCIAL OFFICER Julius Nalas DIV 1SION DIRECTOR Casia Sinco IIUl21.AU CI11I:h Keith NicCarth} SAP["rV PROGRANI MANAGER I�LORIDA DITARTMLNi� p�h rINANCIA>a sh,Rvfcrs DIVISION OF STATE, FIRE MARSHAL, 200 East Gaines Street - Tallahassee, r1orida 32399-0342 Tel.850A13-3644 fax.850.410-2467 THIS CIR"C'II'lES'I'1IA`C: ccR�hIEICATi; Or coNIPhTNr..Y OFFICIAL COPY I3enjalnin D hlwell 10956 Enterprise Ave Bonita Springs I'I., 34135 BUS11yFSS C)RGANI�ATION: I-Iaskin Inc. Contractor V means it contractor whose business is limited ro the execution of contracts requiring the ability to fabricate, install, inspect, alter, repair and service the underground piping; for a fire protection system using water as the extinguishing agent beginning at the point of' service as defined in the act and ending no more than I foot above the finished [loon. Issue late: Type: Class: County: License/permit #t: Expiration Date. 07/O I /20 l 8 09 14 Lee 063009-0001-2008 06/30/2020 Chief I(Illancial Officer vee Coup y mac. Tax Co %r tor stato of f,o%6 Dear Business Owner: Local Business Tax Receipt SU000775 Your 2019-2020 Lee County Local Business Tax Receipt is attached below for account number 8402585. If there is a change in one of the following, refer to the instivctions on the back of this receipt. • Business name • Ownership • Physical location • Business closed This is not a bill. Detach the bottom portion and display in a public location. I hope you have a successful year. Sincerely, Lee County Tax Collector ----------------------- ------------------------------- �- LEE COUNTY LOCAL BUSINESS TAX RECEIPT Account Number: 8402585 State License Numbel : CUCO5'7283 ifstate license has changed, contact our office at 239,533.6000 Location: I0956 ENTERPRISE AVE BONITA SPRINGS FL 34135 HASKINS INC HASKINS HARLAN 10956 ENTERPRISE AVE BONITA SPRINGS FL 34135 Account Uxpires: September 30, 2020 the business UNDERGROUND UTILITY &EXCAVATION CONTRACTOR -CERTIFIED THIS LOCAL BUSINESS'TAX RECEIPT IS NON REGULATORY 2019 FLORIDA PROFIT CORPORATION ANNUAL REPORT DOCUMENT# 574159 Entity Name: HASKINS, INC. Current Principal Place of Business: 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 Current Mag Address: 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 US FEI Number: 59-1844470 Name and Address of Current Registered Agent: ELWELL, BENJAMIN 10956 ENTERPRISE AVENUE BONITA SPRIGS, FL 34135 US FILED Jan 09, 2019 Secretary of State 5115902585CC Certificate of Status Desired: No The above named entity submits this statement for the purpose of changing its registered office or registered agent, or both, in the State of Florida. 01/09/2019 SIGNATURE: BENJAMIN ELWELL Date Electronic Signature of Registered Agent Officer/Director Detail Title PT Title VP Name ELWELL, BENJAMIN Name MACPHEE, RYAN Address 10956 ENTERPRISE AVENUE Address 10956 ENTERPRISE AVENUE City -State -Zip: BONITA SPRIGS FL 34135 City -State -Zip: BONITA SPRIGS FL 34135 Title CFO Title SECRETARY Name HASKINS, HARLAN Name LAGO, MABEL Address 10956 ENTERPRISE AVENUE Address 10956 ENTERPRISE AVENUE City -State -Zip: BONITA SPRGS FL 34135 City -State -Zip: BONITA SPRIGS FL 34135 I hereby certi/y that the information indicated on this report or supplemental report is true and accurate and that my electronic signature shall have the same legal effect as if made under oath; that 1 am an officer or director of the corporation or the receiver or trustee empowered to execute this report as required by Chapter 607, Florida Statutes; and that my name appears above, or on an attachment with all other like empowered. SIGNATURE: BENJAMIN ELWELL Electronic Signature of Signing Officer/Director Detail PRESIDENT 01 /09/2019 Date Detail by Entity Name eartment_r,f State / Dj_visi�n_o_f_Cnroratinrls / Search Records / Search try Entity Nan3_e_ / Previous On List Nex On Liss Detail by Entity Name Florida Profit Corporation HASKINS, INC. Document Number FEI/EIN Number Date Filed State Status Last Event Event Date Filed Event Effective Date Principal Address 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 Changed: 02/02/1998 Mailing Address 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 (del n,i_� 7 to Llst haskins SearcA 574159 59-1844470 05/31 /1978 FL ACTIVE AMENDMENT 06/20/2005 ONE Changed: 02/02/1998 Registered Agent Name &Address ELWELL, BENJAMIN 10956 ENTERPRISE AVENUE BONITA SPRGS FL 34135 http://search.sunbiz.orgJ...teld=domp-574159-78b8fIcc- lad0-498I-a%3-6ca6fW8t7e&searchTerm=hask ins&IistNameOrder=HASKINS%202396170[6/21/2020 3:34:45 PM] Detail by Entity Name Name Changed: 01/09/2019 Address Changed: 04/22/2016 Officer/Director Detail Name &Address Title PT ELWELL, BENJAMIN 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 Title VP MacPhee, Ryan 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 Title CFO Haskins, Harlan 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 Title Secretary Logo, Mabel 10956 ENTERPRISE AVENUE BONITA SPRGS, FL 34135 Annual Reporis Report Year 2018 2019 2020 Document Images Filed Date 01 /12/2018 01 /09/2019 01 /06/2020 0110C�120A---ANNUAL REPC7ftT Q1 /09/2Q19 _AIVR1U�,t__R_EPC�I�.T t71t12/2Q1f3 --ANNUAL}ZEPOF�1� Q1l11 'Z�11_7 -- ANNAAL f_3_FLL_-1-'_n�T (i4/22/20�G�_A�1(EfDEL�_f�NNUAL f�EPOET (11/711?016 --ANNUAL_ RFP�RT View image in PDF fonrtat View image in PDF format Viev�r image in PDF' format View image in PDF fnr+r�at View image in PDF format View i+r�age in PDF format http:/(search.sunbiz.org/...teld=domp-574I59-78b8f1 cc-1 ad0-4981-a963-6ca6fba78f7e&searchTenn=haskins&IistNameOrder—HASKINS%202396170[6/21/2020 3:34:45 PM] Detail by Entity Name 02/06/2015 -- ANNUAL REPORT 01//07/20.1A_-_._ANNUAL REPORT. 06/03/2013 - AMENDED ANNUAL REPORT 01/2U2013 ANNUAL REPORT 08124/2012 -- ANNUAL REPORT 01 / 10/2012_== AN L� UAL _REPORT 01/1712011 -- ANNUAL REPORT 12/16/2010 -- ANNUAL REPORT 02118/201Q. ANNUAL REPS 01/11/2010 -- ANNUAL REPORT 01/19/2009._ �AN_NUALREPORT 01/04/2008 -- ANNUAL REPORT 11Q3/2QC7 =_ALANNU IB_F_PORT. i?1/09/20t76.-- ANNUAL REPORT 06/2'n,`2005=- A encirlie It Q1/13/2005 ANNUAL REPORT 01l2F312U04 ---_ANNUAL REPORT 041/21/2.003_�ANNUAI _Rf PO.RT 01/27/2002 -- REPORT NINANNUAL 01/29/2001 -- ANNUAL REPORT` 0' 0212 00 -- ANNt AL REPORT 03/17/1999__�1P�N_UAL REPORT 02/02i1998 -- ANNUAL REPORT 02_/2.41'i997 -- ANNUAL REPORT 01/2 11 96-- N UALRE'OjTT 01/24/1995 _- ANNUAL REPORT F_reyio�ts._Ctn.._Lis_� Next On_Li.�i R 15 No Name History View image in PDF format View image in PDF format VieON w image in PDF foreeee�mat View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PL?F format View image in PDF format I View image in PDF format View image in PDF format Vie+,v image in PDF format Viev✓ image in PDF format View image in PDF format F3eturn_[o__Lst haskins 50a,U http://search.sunbiz.org/...teld=domp-574159-78b8f1 cc-1 ad0-4981-a963-6ca6f6a7817e&searchTerm=haskins&IistNameOrder—HASKINS%202396170[G/21/2020 3:34:45 PM] Name Greg Collier Ben Elwell Personnel Category Construction Superintendent Project Manager 10 Construction Services Agreement: Revised 072118 (v6) Bond No. 30074186 lvALDORFF INSURANCE & BONDING July 1, 2020 Collier County Board of County Commissioners 3339 Tamiami Trail E Naples, FL 34112 RE: Haskins, Inc. Bond No. 30074186 Project: 20-7752, Hickory Road Water Main Improvements, Collier County, FL To Whom It May Concern: Please be advised that this letter will serve, as confirination to date the performance bond, payment bond and power of attorney on the above referenced project that our client, Haskins, Inc., is going to perform. Please make sure the date is the salve date of the contract or later. If there are any questions or need for further information please contact us. Sincerely yours, Paul A. Locascio Attorney -In -Fact Western Surety Company MAIN OFFICE 45 EGLIN PARKWAY, NE SUITE 202 FORT WALTON BEACH, FL 32548 (850) 581-4925 FAx (850) 581.4930 TOLL FREE: (800) 342-7621 Trusted Choice0 1110 NW 6TH STREET GAINESVILLE, FL32601-4247 (352) 374-7779 FAx (850) 581-4930 TOLL FREE: (888) 901-3841 WWW.WALDORFFI NSURANCE. COM FRONT PAGE OF PUBLIC PAYMENT & PERFORMANCE BOND In compliance with F.S. Chapter 255.05(1)(a) Bond No.: 30074186 Contractor Name: Haskins, Inc. Contractor Address: 10956 Enterprise Avenue, Bonita Springs, FL 34135 Contractor Phone No: (239)947-1846 Surety Company Name: Western Surety any Surety Company Address: 151 North Franklin Street, Chicago, IL 60606 Surety Company Phone No: Agent Name: Waldorff Insurance & Bonding Inc. Agent Address: 1110 NW 6th Street Gainesville, FL 32601 Agent Phone No: �352) 374-7779 Obligee Name: Collier County Board of County Commissioners Obligee Address: 3339 Tamiami Trail E, FL 34112 Obligee Phone No: Bond Amount: $1,377,246.50 Contract No: (if applicable) 20-7752 Description of Work: HickQa Road Water Main Improvements Project Address: Collier County, FL FRONT PAGE All other bond page(s) are deemed subsequent to this page regardless of any page number(s) that may be pre-printed thereon. EXHIBIT 13-1: PUBLIC PAYMENT BOND ITB# 20-7752 Bond No. 30074186 Contract No. 20-7752 KNOW ALL MEN BY THESE PRESENTS: That Haskins, _Inc. _ 10956 Enteriorise Avenue, Bonita Springs, FL 34135 as Principal, and Western Surety n as Surety, located at 151 North Franklin Street, _Chicago, IE06 (Business Address) are held and firmly bound to Collier County Board of County Commissioners as Obligee in the sum of ($ 1,377,246.50 _) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally, *One Million Three Hundred Seventy -Seven Thousand Two Hundred Forty -Six and 501100 WHEREAS, Principal has entered into a contract dated as of the day of 20 with Obligee for 20-7752 Hickory Rd Water Main Improvements in accordance with drawings and specifications, which contract is incorporated by reference and made a park hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND Is that if Principal; Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of feet Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event wit: the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN ,,'IVI NESS WHEREOF, the above parties have executed this instrument this S�day of 20 ZQ , the name of each party being affixed and these presents duly signed by its under -signed representative, pursuant to authority of its governing body. 11 Construction Services Agreement: Revised 072118 (A Band No. 30074186 Signed, sealed and de In the presence of: PRINCIPAL Haskinsalln . BY: NAME. yan ac ee ITS; STATE OF Florida COUNTY OF ee The foregoing instrument was ackriMlledged before me, bY_me ns of physical presence or U1 online npa�tarr��xation, this �� day of ] 20 ZD A by Ryan MacPhee - as is esi ht " Of Haskins Inc. a Florida corporation, on behalf ofAthe corporation. .He/she is personally known to me OR has produced _ _ as identification and slid (did not) take an oath. �Q My Commission Expires: 02/13/2023 (Signatu .e of Notary Public oMu. .pvg:• MABEL LAGO zNotary Public - State of FloridaCommission k GG 269100 . My Comm. Expires Feb 13. 2023 Bonded through Natioval Notary Assn. (AFFIX OFFICIAL SEAL) ATTEST; Witnesses to Surety NAME: Mabel Lago (Legibly Printed) Notary Public, State of Commission No.: (Printed Name) (Business Address (Authorized Signature) (Printed Name) 12 Construeiion Services Agreement: Revised 072118 (v8) Bond No. 30074186 Western Surety Company OR As Attorney In Fact (Attach Power of Attorney) Paul A. Locascio Witnesses (Printed Name) 151 North Franklin Street Chicago, IL 60606 _ .. (Business Address) 312-822-5000 (Telephone Number) STATE OF Florida COUNTY OF Alachua The foregoing Instrument was acknoy�ledged before me y Bans of U physical presence or ❑ online notarization, this �� day of � 20 ZD, by Paul A. Locascio , as _ orne Inln-Fact' of VVestern Surety Company a _S6uth Daota _ _ corporation, o_n behalf of the corporation. He/she is personally known to me OR has produced personally known _ as identification and did (did not) take an oath. My Commission Expires: 12/17/22 TRAVA RIDLON NOTARY PUBLIC STATE OF FLORIDA No. GG284959 MY COMMISSION EXPIRES DEC. 17, 2022 (AFFIX OFFICIAL SEAL) (Signature of Notary Public) Name: Trava Ridlon (Legibly Printed) Notary Public, State of: FL Commission No,: GG284959 13 construction Services Agreement: Revised 07211a (v6) EXHIBIT B-2: PUBLIC PERFORMANCE BOND IT13#20.7752 Bond No, 30074186 Contract No. 20-7752 KNOW ALL MEN BY THESE PRESENTS: That Haskins, Inc. 10956 Enterprise Ave., Bonita Springs, FL 3413A Principal, and Western SuretV C;ampan, as Surety, located at .1.51 North Franklin Street, Chicago, IL 60606. (Business Address) are held and firmly bound to Collier County Board of County Commissioners, as Obligee in the sum of One Million Three Hundred Seventy -Seven Thousand Two Ffundred Forty -Six and 501100 ($ 1,377,240,50 , ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of 20 1 with Obligee for 20-7752 Hickory Rd Water Main Imnroyements _ in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract; and 2. Pays Obligee any and all losses, damages, costs and attorneys' fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not of fect Sureties obligation under this B and. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. in no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20 , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 14 , Construction Services Agreement: Revised 072118 (v6) `C Band No, 30074186 Signed, sealed elive in the }gyres of: ses as to Principal Florida STATE OF _ COU hlTY OF Lee PRINCIPAL .. \ NAME: MacPhee ' The foregoing Instrument was ackllt(edged before me bye ns ofphystcal presence or Cl online notarization, this day of a20 LD, by Ryan? MacPhee SVarawPrac_ideat of Haskins Inc. a Florida corporation, on behalf of ttteN Rrporation. Helshe is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: 02/13/2023 (AFFIX OFFICIAL SEAL) HIABEL LAGO :° • �: Notary Public State of Florida o Commission # GG 2b9100 My Comm. Expires Feb 13, 202t Bonded through National Notary AM: (Signature of Notary Public) Mabel Lago Name: - — (Leglbly Printed) Notary Public, State of: Commission No.: t5 consbucti©a SeMces Nreement: Revised 072110 (v8) Bond No. 30074186 ATTEST: Witnesses as to Surety j. OR Witnesses STATE OF Florida COUNTY OF Alachua SURETY: (Printed Name) (Business Address) (Authorized Signature) (Printed Name) Western Surety Company As Attorney in Fact (Attach Power of Attorney) Paul A. Locascio (Printed Name) 151 North Franklin Sti.et Chicago IL 60606 (Business Address) — . . . • . 312-822-5000 " - ,ii�114Syh� (Telephone Number) The foregoing instrument was acknoyedged before me online n tarization, this 1 day of Paul A. Tocascio of Western ure y ompany_ a Sou behalf of the corporation. He/she Is personally r)ersonaliv known take an oath. My Commission Expires:12/17/22 TRAVA RIDLON NOTARY PUBLIC STATE OF FLORIDA NO. GG284959 MY COMMISSION EXPIRES DEC. 17, 2022 (AFFIX OFFICIAL SEAL) by-mie ns of M physical presence or 20, by as Atto nev-in-Fact th Dakota corporation, on known to me OR has produced _ — as identification and did (did not) (Signature of Notary Public) Trava Ridlon (Legibly Printed) Notary Public, State of: FL Commission No.:GG2$459- 19 Construction Services Agreement: Revised 07211 S (A) qA Bond No. 30074186 Western Surety Company POWER OF ATTORNEY APPOINTrgG INDIVIDUAL ATTORNEY-LN-FACT Know All Men By These Presents, 'that WESfMRIN 5111UL,TY COMPANY, a Sottth Dakota corputation, is a duly organized and existing curporattion having its prhtcipul office in (lie City of Sioux balls, and Shute of South Dakota, and that it (toes by virtue of the signatutc and seul trerein affixed hereby make, constitute and appoint L. Dale '4' aIdorlf; Bentjwnitn H French, Pamela L. Jarman, Paul A, Lticasdo, K. Wayne, Walker, Rebekah G Wolf, G7yde D Hare, ludh idually Of Fort Walton Reach, FL, its true and lawfitl Attorney(s)-in-Fact Nvith fall power and antl€only hereby conferred to sign, seal and execute for and on its behalf bonds, undedakirtgs and other obligatory ittstrutnents of similar nature - In Unlimited Amounts - and to bind it thereby as fully and tothe same extent us if such histi uments were signed by a duly authorized officer of the corputulian and all the acts of said Att,orticy, pursuant to the authority bcrcby given, arc hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of tha By -Law printed on the reverse bereof, duly adopted, as indicated, by the sharcltoldcts of the corpowoon. In Wilitess Whereof, WESTERN SURETY COMIANY has caused these presents to be signed by its Vice President and its corporale seat to be hereto afllxcd on this 291h day of December, 2015. K WESTERN SURETY COMPANY _��il,P9Aq�4.e l"°°'10� aul T, Bntf3att. Vice President State of South Dakota ss County of lblimmhaha€ On this 29th day of December, 2015, before me personally carte Paul T. Bruflat. to me known, who, being by me duly sworn, did depose and say: that hu resides in the City of Sioux Falls, Slate of South Dakota, that he is the Vice President of IUSTERN SUKETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation,, that the real aftUrd to the said instnrment is 3hacb corporate scat; that it was so affixed pursuant to authority given by the Board of Director of said corporation and that he signed his name thereto pttrsthanl. to like authority, and acknowledges soma to be the art and deed of said cotporation. My commission expires June: 23. 2021 J. M4NR SOUTNVs'n4i0YaIF U �p 66JiH11 CERTIFICATE I, L. Nelson, Assistant',Sccrelary'0f.WESTERN SURETY COMPANY do hereby certify that tilt Power of Attorney bereinabove set forth is still in force, and further etWfy tint the=P) ;Lau' of the corporation printed on tire reverse hereof is still in force, lit testimony whereof f have (hereunto subscribed my name and affixedtlle'scgkd(be s3id'coj;ilrafion this day of WESTERN SURETY COMPANY $£A ,a ' ilsr; e �. i-'i'' 4�4ti I,. Nelson, Assistant Secretary Penu F4:so-7•zo 12 EXHIBIT B-3• INSURANCE REQUIREMENTS The Contractor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Contractor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Contractor waive against each other and the County's separate Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Contractor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Contractors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number/contract number and title. The General Liability Policy provided by Contractor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Contractor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County, The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Contractor has any self -insured retentions or deductibles under any of the below listed minimum required coverage, Contractor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or deductibles will be Contractor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Contractor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non -renewal on the part of the insurance carrier or the Contractor. The Contractor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or material change in coverage or limits received by Contractor from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Contractor hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 17 Construction Services Agreement: Revised 072118 (v6) Should at any time the Contractor not maintain the insurance coverages) required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages) and charge the Contractor for such coverages) purchased. If Contractor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Contractor under this Agreement or any other agreement between the County and Contractor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages) purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverages) shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Contractor shall furnish to the County renewal or replacement Certificates) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Contractor to provide the County with such renewal certificates) shall be considered justification for the County to terminate any and all contracts. 18 Construction Services Agreement: Revised 072118 (v6) Collier County Florida Insurance and Bonding Requirements Insurance I Bond Type Required Limits 1. ❑ Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof of exemption. An application for exemption can be obtained online at https://apps,fldfs.com/bocexempt/ 2. ❑Employer's Liability $ ' `single limit per occurrence 3. ❑Commercial General Bodily Injury and Property Damage Liability (Occurrence Form) patterned after the current $ single limit per occurrence, $2,000,000 aggregate for Bodily Injury ISO form Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. ❑ Indemnification To the maximum extent permitted by Florida law, the Contractor/Vendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor/Vendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. 5. ❑Automobile Liability $ 'Each Occurrence; Bodily Injury &Property Damage, Owned/Non-owned/Hired; Automobile Included 6. ❑ Other noted: insurance as ❑Watercraft 0 Per Occurrence ❑ United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑ Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑ Aircraft Liability coverage shall be carried in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. $ Per Occurrence ❑ Pollution 0 Per Occurrence ❑ Professional Liability $ 'Per claim & in the aggregate $1,000,000 per claim and in the aggregate $2,000,000 per claim and in the aggregate ❑ Project Professional Liability $, Per Occurrence ❑ Valuable Papers Insurance $ Per Occurrence 19 Construction Services Agreement: Revised 072118 (v8) z j..y 7 ❑ Cyber Liability $ Per Occurrence ❑ Technology Errors & Omissions $ Per Occurrence ❑ Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. ❑ Performance and For projects in excess of $200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038, 9. ❑Consultant shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Consultant shall provide County with certificates of insurance meeting the required insurance provisions. 10. ❑ Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. 11. ❑The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12. ❑Thirty (30) Days Cancellation Notice required. Consultant's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. Name of Firm Consultant Signature Print Name Insurance Agency Agent Name Date Telephone Number 20 Construction Services Agreement: Revised 072118 (v6) EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF (COLLIER) STATE OF (FLORIDA) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated ,20 for the period from to .This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. Witness President Witness STATE OF COUNTY OF CONTRACTOR BY: ITS: DATE: [Corporate Seal] The foregoing instrument was acknowledged before me by means of ❑physical presence or ❑online notarization, this day of 20 by as of 0 corporation. He/she is personally My Commission Expires: (AFFIX OFFICIAL SEAL) corporation, on behalf of the known to me OR has produced as identification and did (did not) take an oath. (Signature of Notary Public) NAME: (Legibly Printed) Notary Public, State of Commissioner No.: 21 Construction Services Agreement: Revised 072118 (v6) EXHIBIT D FORM OF CONTRACT APPLICATION FOR PAYMENT Collier Count Board of County Commissioners the OWNER or Collier Count Water -Sewer Owner's Project Bid No. Manager's Name: Project No. Count 's Division Name Purchase Order No. Submitted by Contractor Application Date: Representative: Name Contractor's Name & Payment Application No. Address: Original Contract Time: Original Contract Price: $ Revised Contract Time: Total Change Orders to Date: $ Revised Contract Amount: $ Total Value of Work Completed & $ Stored to Date: Retainage @10% $ Retainage @ 10% through [Insert $ through [Insert Date] date] Retainage @ % $ Less Retainage $ after Insert date Total Earned Less Retainage $ Less previous payment(s Percent Work Completed % AMOUNT DUE THIS $ to Date: APPLICATION: Percent Contract Time % Completed to Date: Liquidated Damages to $ Remaining Contract Balance $ Be Accrued ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid,for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. Contractor's Name Contractor's Si nature: Date: Shall be signed by an authorized Type Title: .Jjre resentative of the Contractor. Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Design Professional's Name: Signature: Date: Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Owner's Project Manager Name: Signature: Date: 22 Construction Services Agreement: Revised 072118 (v6) 'EXHIBIT D D.n nr 1J�m SCHEDULE OF VALUES Project Number: Date: Period To: _ _.... ITEM NUMBER DESCRIPTION SCHEDULED VALUE WORK COMPLETED STORED MATERIALS TOTAL COMPLETEE &STORED TO DATE PERCENT COMPLETE BALANCE TO FINISH 10% RETNNAGE _% RETNNAGE (redwedrate) TOTAL RETNNAGE WTHHELD PREVIOUS APPLICATIONS THIS PERIOD THRU DATE SINCE DATE TOTALS * Explanation for the two columns under Previous Applications: The Thru Date is where you will place all information until the contract is complete unless a release or reduction of retainage issue col toplay. If this happens, all information up to the date of the %change in retainage is placed in the Thru Date column. Information after that date is placed nthhe Since Date column. This states what has happened since the change in retainage. 23 Construction Services Agreement: Revised 072118 (v6) Exhibit D (Continued) Stored Materials Record Formula:A+B-C-D=E A B C D E Date Description Supplier. Invoice Number Previously Received Received This Period Previously Installed Installed This Period Balance To Install 24 Construction Services Agreement: Revised 072118 (v6) EXHIBIT E: CHANGE ORDER An electronic data entry form may be found at: Change Order Form Purchase+Order#: Project#: Contract#:�� Change#: ���JJJ ContractorMrm Name: _ _ Frojeet telanager Nan1e�— rDrkginsl C�ntrsct r/^,r?: Q-de An�unt Current BCC AmovedAn*unt Current "ACcnlacUVVctk Order Amcunt Gclbr "nxlunt f this Chang= Revi dContraUVIcrk »rdr Tots] �0•00 _ n 0.00 Pro Name: department: �------� l BGC Apprc,•al GsL; A:gsnda It=rtz #. Last BCC Approval Gat=; Agends Item-4 SAF` °Ucn"ctExpiration lists (Ivtsst=r'S *.C,. TctsI Ch3Ns. frcniCri3inalAnx nt *c 0+ Chsng=frcnzCVfent BCC Apprv�"ed Amour, .a-�.i.r.ni ,,^hnrnafmmCLrreniAncunt Completion Date Description of th=Task(sj Change, and Rationale for the Change �jI �� Last A Approved Revised Date I NOtiCe to PfOGei� Original Date pp �r.-y,tlt>are�-t Data Completion Date �� Select Tasks ❑' Add newtask(s) ❑',Deletetask(s) 0 Changetask(s) [I Other •Y,>'f of Days Added Provide a response to the following: f.j detai4gd and specific explanation7rationale of the requested change(s) to the tasks}and 1 or the additional days added (if raquestedj; 2.1why this change was not ncluded in the o� ginal cantraoc and r describe the impact if Prepar+:d by: r y. f.c pt re .i Ff Ch, , Ot r_ a. or tit t ar+t ai�st?.,r o rrir ''d�nrY r rti �-b�� saai t c, _ito 'lth=s m= t= 01 r c;,r� r_ �� ccr r ,� sr ti• r tr t t a+rrk ra * ra _ c:,v= s f 110 s si h mat a: ri= ui � 3r tt^ .xpt ram. Tr=_ aci i tsr1, fay nth r'rira t Eir_n_ta �ai�Ila ina1a_.t m r.te�ia D=s rPsafe�snrxar"ss.ecaaive'311C tntFcchanq_5_:ici h��rfn.irc.sr2w7��m5f.<tsmps�=n�d_ta> D=_t-: Accepted by. lcabl ti _ (C+�ntrcI rlVSr,i0r, CeAnss<13ni D_siar<E`reie 'or ,ar,stJam=.fF�rn� pret ^t p.. Dale: Approved by: Approved by: 25 Construction Services Agreement: Revised 072118 (v6) EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date Design Professional's Project No. This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 26 Construction Services Agreement: Revised 072118 (v8) RESPONSIBILITIES: OWNER: CONTRACTOR The following documents are attached to and it a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on By: Design Professional Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 By: CONTRACTOR Type Name and Title OWNER accepts this Certificate of Substantial Completion on By: Type Name and Title ,20 27 Construction Services Agreement: Revised 072118 (v8) EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: Contractor: The following items have been secured by the for the Project known as Date: and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Calendar Substantial Completion Time as set forth in the Agreement:Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner (attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As -Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: (attach to this form). issued on 8. Certificate of Substantial Completion issued on 9$ Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13, Finished Floor Elevation Certificate provided to Owner: 14, Other: If any of the above is not applicable, indicate by N/A. explanation. Acknowledgments: By Contractor: By Design Professional: By Owner: If NO is checked for any of the above, attacn (Company Name) . (Signature) (Typed Name & Title) (Firm Name) (Signature) (Typed Name &Title) (Department Name) (Signature) (Name & Title) 2s Construction Services Agreement: Revised 072118 (v6) 1. INTENT OF CONTRACT DOCUMENTS. 1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and installed as part of the Work, whether or not called for by the Contract Documents. 2. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work -site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 29 Construction Services Agreement: Revised 072118 (v6) 2I Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub -Section 2.2 as the "Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the. course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. 3. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be 30 Construction Services Agreement: Revised 072118 (v6) �---.. A j limited to the hours of 7 a.m. to 7 p.m., Monday through Saturday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 462 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 444 Contractor shall submit its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218,735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 445 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re -submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is 31 Construction Services Agreement: Revised 072118 (v6) stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent (50%) completion subject to the guidelines set forth in Florida Statute 255,078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. licationshall be accompanied 4.8 Each Application for Payment, subsequent to the first pay app, by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub -subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub -subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non- payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 32 Construction Services Agreement: Revised 072118 (v6) 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non -liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5.3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off -set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 33 Construction Services Agreement: Revised 072118 (v6) 7. SUBMITTALS AND SUBSTITUTIONS. 7.1 Contractor shal I carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered bye CManager ontraorotocfurnishgi at Contractor's expense ng t xpensehe oadditional sed tdata abouute* The Project thepropo proposed may require Con substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the by substitute proposed submission to and reviewent to at indicated or by the Project Manaiger shallhbe he same tract as those provided ocuments. The procedures for sub herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will 34 Construction Services Agreement: Revised 072118 (v6) � �, record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub -Contractor's personnel; d The number of Contractor's anSub-Contractor's personnel present and wo 8.1.4 rking at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1,8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. Contractor The daily log shall not constitute nor take the place of any notice required to be given by to Owner pursuant to the Contr act Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features 35 Construction Services Agreement: Revised 072118 (v6) (e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The "As -Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As -Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT. Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112=5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 9. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material -men, as well as coordinating its Work with all 36 Construction Services Agreement: Revised 072118 (v6) work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9A In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work 37 Construction Services Agreement: Revised 072118 (vfi) Directive. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub -subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or sub -subcontractor for field and home office overhead is included in the markups noted above. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight (48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pendency of any Claim. 38 Construction Services Agreement: Revised 072118 (v6) 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnifyI and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit 0-3 to the Agreement. 39 Construction Services Agreement: Revised 072118 (v6) Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit 13-3. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes), If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 Bexecuting and entering into this agreement, the Contractor is formally acknowledging y without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seg. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet - based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: • Commodity based procurement where no services are provided. Where the requirem ent for the affidavit is waived by the Board of County Commissioners Contractors /Bidders are required to enroll in the E-Verify program, and provide acceptable evidence ' ' proposal. Acceptable oI their enrollment, at the time of the submission of the Contractors/bidders evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Contractors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. responsive. / Contractor's proposal may De aeenrGu rl.,"- 40 Construction Services Agreement: Revised 072118 (v6) Additionally, Contractors shall require all subcontracted Contractors to use the &Verify system for " "Exceptions to the programclause above. all purchases not covered under the For additional information regarding the Employment Eligibility Verification System (&Verify) program visit the following website: http://www dhsgov/E~Verify_• It shall be the Contractor's responsibility to familiarize themselves with all rules and regulations governing this program. Contractor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et se . and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the laws referenced herein orshallpihave the d scetiond toitunilate unilshall aterally natetute a asaid ch f award the the agreement agreement and the County immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove allappliances, rubbish and waste materials from and about the Project site, as well as all tools, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subto the to tcond'tionhe oequal2.3 atoothat existing , any such iatphe t menof Cont ac ts so oer's shall be restored by Contractor commencement of the Work. 16, ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. Any attempt to assign or otherwise transfer this Ag r ement,r any part herein, without the Owner's consent, shall be void. If Contractor does, with app , assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County to the Work th d feughes, including license fees, permit fees, impact fees or inspection fees applicable internal budget tractor i sr Contractor lfor acquiring all perm tssponsible r Owner may require paying for permits issued the Collier County, but Contractor is responsible deliver internal budget transfer documents to applicable Collier County agencies owhendt e Contractor is acquiring permits. Owner will not be obligated to pay for any permits Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 41 Construction Services Agreement: Revised 072118 (v6) 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default %J the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s) within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials, equipment, supplies, and other items therefore or re -letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 42 Construction Services Agreement: Revised 072118 (v6) 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below . 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the a e9rbut innno everecover from thent t shall ContractoObener enti Iedrrtont for paymentrfopWork not erformed through the termination , performed or any other damages from Owner. 19, TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 1962 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work (or designated portion thereof) to Owner, after conferring with the Design Professional, does determine the status of completion. If Own not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager 43 Construction Services Agreement: Revised 072118 (v6) shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall IN the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch -list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch -list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: (1) Receipt of Contractor's Final Application for Payment. (2) The Release and Affidavit in the form attached as Exhibit C. (3) Consent of surety to final payment. (4) Receipt of the final payment check list. (5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in s uch form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 44 Construction Services Agreement: Revised 072118 (v6) 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re -inspection fees and costs; to the extent such re -inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight (8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents, 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shal I as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non -defective Work. Contractor shall bear all direct, indirect and consequential 45 Construction Services Agreement: Revised 072118 (v6) costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstructio n. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall 46 Construction Services Agreement: Revised 072118 (v6) include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit A-1 is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.13, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 47 Construction Services Agreement: Revised 072118 (v6) 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Are Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, 48 Construction Services Agreement: Revised 072118 (v6) Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner faces are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5.7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5.9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend apre-construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or 49 Construction Services Agreement: Revised 072118 (v6) Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre -construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right -of -Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.net/purchasing. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax kdirect and may wish to generate sales tax savings for the Project, Owner reserves the right to mae purchases of various construction materials and equipment included in the Work ("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing) warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as al I other warranties provided by Contractor pursuant to the terms of 50 Construction Services Agreement: Revised 072440 (v6) the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be "qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self -performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub -subcontractor performing any portion of the Work, as well as maintain a log of all such licenses. All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of 51 Construction Services Agreement: Revised 072118 (v8) Owner upon termination of Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third -party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its sub - subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on -site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor (including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be caused by Owner or Design Professional or attributable to Owner or Design Professional and including claims based on breach of contract or negligence, shall be an extension of its contract time. 33.6.2 In the event of a change in the work, the Subcontractor's claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus no more than 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub -subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner, and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 52 Construction Services Agreement: Revised 072118 (v6) 34.1.3 Shop Drawing Submittal/Approval Logs 34.1.4 Equipment Purchase/Delivery Logs 3141.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 3401.10 Equipment Costs 34.1011 Cost Proposal Request 3461,12 Payment Request Records 34.1.13 Meeting Minutes 3461414 Cost -Estimates 34,1015 Bulletin Quotations 3401416 Lab Test Reports 3401.17 Insurance Certificates and Bonds 3401018 Contract Changes 3461,19 Permits 34.1620 Material Purchase Delivery Logs 3441,21 Technical Standards 34.1.22 Design Handbooks 3461023 "As -Built" Marked Prints 3441924 Operating & Maintenance Instruction 3461425 Daily Progress Reports 3441926 Monthly Progress Reports 3461427 Correspondence Files 34.1.28 Transmittal Records 3461429 Inspection Reports 34.1.30 Punch Lists 34.1931 PMIS Schedule and Updates 3401432 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the presentation requirements and format. Presentations may include, but not be limited to, the following information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shal I be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County 53 Construction Services Agreement: Revised 072118 (v6) under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e-mail (DL-FMOPS(a)colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of $500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the Contractor is responsible for all costs. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A "project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid &Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing / will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48-hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials /petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 54 Construction Services Agreement: Revised 072118 (v6) 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision - making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision -making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 55 Construction Services Agreement: Revised 072118 (v6) EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS 56 Construction Services Agreement: Revised 072118 (v6) 1 11.K.f I ACCOR E CERTIFICATE OF LIABILITY INSURANCE I DATE IN E/30/2020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THI: CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIE7 BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZE[ REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject ti the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to th, certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Yarltza Soto BKS Partners PHONE FAX 5216 Summerlin Commons Blvd AIC No Ext: 239-931-3021 A/C No:239-931-5604 Suite 200 ADDRESS: yaritza.soto@bks-partners.com Fort Myers FL 33907-2139 INSURER(S) AFFORDING COVERAGE NAIC # INSURERA: Brid efield Employers Ins Co. 10701 INSURED HASKINC-01 Haskins, Inc. 10956 Enterprise Ave. Bonita Springs FL 34135 INSURER B: National Trust Insurance 20141 INSURERC: FCCI Insurance Company 10178 INSURERD: Indian Harbor 36940 INSURER E, INSURER F COVERAGES CERTIFICATE NUMBER: 548726524 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOI INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THI; CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERM: EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF MM/DD/YYYY POLICY EXP MM/DD/YYYY LIMITS B X COMMERCIAL GENERAL LIABILITY Y GL10004897402 7/1/2020 7/1/2021 EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE OCCUR DAMAGE TO RENTED PREMISES Ea occurrence $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY ❑X PRO- LOC JECT PRODUCTS - COMP/OP AGG $ 2,000,000 $ OTHER: B AUTOMOBILE LIABILITY CA10002608302 7/1/2020 7/1/2021 COMBINED SINGLE LIMIT Ea accident $ 1,000,000 X BODILY INJURY (Per person) $ ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS BODILY INJURY (Per accident) $ X DAMAGE (Pe accident) PROPERTY $ HIRED AUTOS X NON -OWNED AUTOSPIP $ 10,000 C X UMBRELLA LIAB X OCCUR UMB10002608402 7/1/2020 7/1/2021 EACH OCCURRENCE $ 2,000,000 AGGREGATE $ 2,000,000 EXCESS LIAB CLAIMS -MADE DED X RETENTION $ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y / N 0830-56505 7/1/2020 7/1/2021 X PER OTH- STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? N / A E.L. EACH ACCIDENT $ 1,000,000 (Mandatory in NH) E.L. DISEASE - EA EMPLOYEE $ 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ 1,000,000 D Contractors Pollution Liab PECO05016002 7/1/2020 7/1/2021 Each Claim $1,000,000 Claims Made Coverage Defense Costs $1,000,000 Retro Date: 7/1/17 Retention Ind Defens $10,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) As requested by Written Contract; RE: Project # 20-7752 Hickory Road Water Main Improvements Collier County Board of County Commissioners is included as additional insureds with respect to General Liability per form CGL084. 30 Day Notice of Cancellation applies, except 10 days for nonpayment. CERTIFICATE HOLDER CANCELLATION Collier County Board of County Commissioners 3295 Tamiami Trail East Naples FL 34112 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORI THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED II ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD Packet Pg. 798 COMMERCIAL GENERAL LIABIL 11.K.f CGL 084 (10 13) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU - ONGOING OPERATIONS AND PRODUCTS -COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM SGFitUULt (UPI IU Name of Additional Insured Persons or Organizations (As required by written contract or agreement per Paragraph A. below.) Locations of Covered Operations (As per the written contract or agreement, provided the location is within the "coverage territory".) (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II — Who Is An Insured is amended to include as an additional insured: 1. Any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement in effect during the term of this policy that such person or organization be added as an additional insured on your policy; and 2. Any other person or organization you are required to add as an additional insured under the contract or agreement described in Paragraph 1. above; and 3. The particular person or organization, if any, scheduled above. Such person(s) or organization(s) is an additional insured only with respect to liability for "bodily injury', "property damage" or "personal and advertising injury' occurring after the execution of the contract or agreement described in Paragraph 1. above and caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf in the performance of your ongoing operations for the additional insured; or 3. Your work" performed for the additional insured and included in the "products -completed operations hazard" if such coverage is specifically required in the written contract or agreement. CGL 084 (10 13) Includes copyrighted material of the Insurance Services Offices, Inc. with its permission. Page 1 of 3 Copyright 2013 FCCI Insurance Group. Packet Pg. 799 COMMERCIAL GENERAL LIABIL 11.K.f CGL 084 (10 13) However, the insurance afforded to such additional insured(s) described above: 1. Only applies to the extent permitted by law; 2. Will not be broader than that which you are required by the contract or agreement to provide for such additional insured; 3. Will not be broader than that which is afforded to you under this policy; and 4. Nothing herein shall extend the term of this policy. B. The insurance provided to the additional insured does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or 2. Supervisory, inspection, architectural or engineering activities. C. This insurance is excess over any other valid and collectible insurance available to the additional insured whether on a primary, excess, contingent or any other basis; unless the written contract or agreement requires that this insurance be primary and non-contributory, in which case this insurance will be primary and non-contributory relative to insurance on which the additional insured is a Named Insured. D. With respect to the insurance afforded to these additional insureds, the following is added to Section III — Limits of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement described in Paragraph A.1.; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. E. Section IV — Commercial General Liability Conditions is amended as follows: The Duties In The Event of Occurrence, Offense, Claim or Suit condition is amended to add the following additional conditions applicable to the additional insured: An additional insured under this endorsement must as soon as practicable: 1. Give us written notice of an `occurrence" or an offense which may result in a claim or "suit' under this insurance, and of any claim or "suit' that does result; 2. Send us copies of all legal papers received in connection with the claim or "suit', cooperate with us in the investigation or settlement of the claim or defense against the "suit', and otherwise comply with all policy conditions; and 3. Tender the defense and indemnity of any claim or "suit' to any provider of other insurance which would cover the additional insured for a loss we cover under this endorsement and agree to make available all such other insurance. However, this condition does not affect Paragraph C. above. CGL 084 (10 13) Includes copyrighted material of the Insurance Services Offices, Inc. with its permission. Page 2 of 3 Copyright 2013 FCCI Insurance Group. Packet Pg. 800 COMMERCIAL GENERAL LIABIL 11.K.f CGL 084 (10 13) We have no duty to defend or indemnify an additional insured under this endorsement until we receive from the additional insured written notice of a claim or "suit". F. This endorsement does not apply to any additional insured or project that is specifically identified in any other additional insured endorsement attached to the Commercial General Liability Coverage Form. CGL 084 (10 13) Includes copyrighted material of the Insurance Services Offices, Inc. with its permission. Page 3 of 3 Copyright 2013 FCCI Insurance Group. Packet Pg. 801 IJ�(I �Is�ry �/`/��'��r 1'/l��ir� Jrn�r� ✓err, �r,'c pl JJJr J r> > r� L, p )r�r�r� r July 21020 c L NNO LPL 0 :i N Iq 00 N Packet Pg. 802 11.K.g I r j e � .� .� Public Udlrti-PD Depart nerrt Packet Pg. 803 -ERDBU BEACH ROAD I Tamiami 4 Proposed transmission water mai (replaces existing) L 0 W 0 u 2 N le 00 N PubJJr; U lidos Department I Packet Pg. 804 11.K.g I i (� .I � f]�J� er �CJ9 Public Utilf-des Deparimerrr Packet Pg. 805 11.K.g pLjbjJf; Jr Mjp-s Dip lftiffl.'afll Packet Pg. 806 11.K.g Publj,r� U61f6p-s Dpapaftfflefl? Packet Pg. 807