#18-7432-LA (Cribb Philbeck Weaver Group, Inc.)PROFESSIONAL SERVICES AGREEMENT
(FIXED TERM CONTINUING CONTRACT)
❑■ CCNA ❑ N GGNA
Contract # 18-7432-LA
for
" Professional Services Library Landscape Architecture Cateqo
THIS AGREEMENT is made and entered into thisc�e day ofrR04 2020
by and between the Board of County Commissioners for Collier County, -lorida, a political
subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and
Cribb Philbeck Weaver Group, Inc.
authorized to do business in the State of Florida, whose business address is
3918 N. Highland Avenue, Tampa, FL 33603 (hereinafter
referred to as the "CONSULTANT" and/or "CONTRACTOR")
WITNESSETH:
WHEREAS, the COUNTY desires to obtain the CONSULTANT's services expeditiously
when a need arises in connection with a Collier County project; and
0 WHEREAS, Section 287.055, Florida Statutes, Consultant's Competitive Negotiation
Act, "CCNA", makes provisions for a fixed term contract with a firm to provide professional
services to a political subdivision, such as the County; and
0 WHEREAS, the COUNTY has selected CONSULTANT in accordance with the
provisions of Section 287.055, Florida Statutes, to provide professional services on a fixed term
basis as directed by the COUNTY for such projects and tasks as may be required from time to
time by the COUNTY.
NOW, THEREFORE, in consideration of the mutual covenants and provisions contained
herein, the parties hereto agree as follows:
ARTICLE ONE
CONSULTANT'S RESPONSIBILITY
1.1. From time to time upon the written request or direction of the COUNTY as hereinafter
provided, CONSULTANT shall provide to the COUNTY professional services (hereinafter the
"Services") as herein set forth. The term "Services" includes all Additional Services authorized by
written Amendment or Change Order as hereafter provided.
1.2. CONSULTANT acknowledges and agrees that services under this Agreement are to be
requested by the COUNTY on an as -needed basis only, and COUNTY makes no representation
or guarantee to CONSULANT that the COUNTY will utilize CONSUTTANT'S services
exclusively or at all.
Page 1 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
1.3 All Services to be performed by the CONSULTANT pursuant to this Agreement shall be in
conformance with the scope of services, which shall be described in a Work Order issued pursuant
to the procedures described herein. The form of the Work Order is set forth in attached Schedule
A. Reference to the term "Work Order" herein, with respect to authorization of Services, includes
all written Amendments or Change Orders to any particular Work Order. The CONSULTANT
acknowledges and agrees that each individual Work Order shall not exceed $200,000 or the
maximum sum allowable by law under Florida's Consultants' Competitive Negotiation Act, Section
287.055, Florida Statutes, as amended, whichever is greater, and as agreed upon by the parties.
Fp� Work order assignments for CCNA contracts shall be made in accordance with the current
Procurement Ordinance, as amended.
1.4. FE-1 (Multi -Award) SELECTION OF CONSULTANT FOR WORK ORDERS. All
CONSULTANTS subject to this Agreement, including CONSULTANT, shall be placed on a
rotation list for professional service, as listed below.
1.4.1. Professional Services Library Rotation
a. Work assignments within each service category are awarded on a rotational basis
by the Procurement Division.
b. For each service category, the Procurement Service Division will place qualifying
firms in the Professional Services Library in the order they are ranked, with the
highest scoring firm placed in the first position in the rotation.
c. As each work assignment is identified the next firm in the rotation will be
offered the opportunity to negotiate that work assignment with the COUNTY's
Contract Administrative Agent/Project Manager.
d. Should a firm decline a work assignment, or be unable to reach a satisfactory
fee negotiation with the COUNTY within a reasonable time frame, the COUNTY
will contact the next firm on the list until the work assignment is successfully
negotiated.
e. Firms will have the option of rejecting one work assignment within each
service category within a twelve (12) month period without penalty. A second
work assignment rejection within any twelve (12) month period will cause the
firm to be skipped in the rotation. A firm who rejects three (3) work assignments
(or is unable to satisfactorily negotiate 3 work assignments) in any twelve (12)
month period may be removed from the service category.
f. Firms wishing to reject a work assignment for any reason must complete a Work
Assignment Rejection Notification Form. A copy of this completed form must
be provided to the Procurement Division by the County's Contract Administrative
Agent/Project Manager.
g. Once a full rotation through all firms in a service category is complete, a method
that attempts to impart an equitable distribution of work among selected firms
will be based on prior dollars awarded; with the firm having received the least
amount of dollars being considered for the next work assignment.
Page 2 of 33
PSA Fixed Tenn Continuing Contract 2017.009 Ver.2
T
1.4.1.1 Professional Services Library — Direct Selection. For work
assignments requiring unique experience or knowledge, including past experience on another
phase of the project, the County's Contract Administrative Agent/Project Manager may formally
request permission to forego the rotation and select a specific firm. This request will require
the completion of a Work Assignment Direct Select Form, which requires the approval of both a
Division Director and the Procurement Services Director. Firms that are directly selected for a
work assignment as a result of this process shall be passed on their next scheduled turn in the
rotation.
1.5. All Services must be authorized in writing by the COUNTY in the form of a Work Order.
The CONSULTANT shall not provide any Services to the COUNTY unless and to the extent they
are required in a written Work Order. Any Services provided by CONSULTANT without a written
Work Order shall be at CONSULTANT's own risk and the COUNTY shall have no liability for such
Services.
1.6. As the COUNTY identifies certain Services it wishes CONSULTANT to provide pursuant
to the terms of this Agreement, the COUNTY shall request a proposal from CONSULTANT for
such Services, said proposal to be in compliance with the terms of this Agreement. If the parties
reach an agreement with respect to such Services, including, but not limited to the scope,
compensation and schedule for performance of those Services, a Work Order shall be prepared
which incorporates the terms of the understanding reached by the parties with respect to such
Services; and if both parties are in agreement therewith, they shall jointly execute the Work Order.
Upon execution of a Work Order as aforesaid, CONSULTANT agrees to promptly provide the
Services required thereby, in accordance with the terms of this Agreement and the subject Work
Order.
1.7. It is mutually understood and agreed that the nature, amount and frequency of the Services
shall be determined solely by the COUNTY and that the COUNTY does not represent or
guarantee to CONSULTANT that any specific amount of Services will be requested or required of
CONSULTANT pursuant to this Agreement.
1.8. The CONSULTANT shall have no authority to act as the agent of the COUNTY under this
Agreement or any Work Order, or to obligate the COUNTY in any manner or way.
1.9. All duly executed Work Orders (including all written Amendments or Change Orders
thereto) are hereby incorporated into and made a part of this Agreement by reference.
1.10. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement
all such licenses as are required to do business in the State of Florida and in Collier County,
Florida, including, but not limited to, all licenses required by the respective state boards and other
governmental agencies responsible for regulating and licensing the professional services to be
provided and performed by the CONSULTANT pursuant to this Agreement.
1.11. The CONSULTANT agrees that, when the services to be provided hereunder relate to a
professional service which, under Florida Statutes, requires a license, certificate of authorization
or other form of legal entitlement to practice such services, it shall employ and/or retain only
qualified personnel to provide such services to the COUNTY.
Page 3 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
1.12. The CONSULTANT designates Grace Harrison, PLA a qualified
licensed professional to serve as the CONSULTANT's project coordinator (hereinafter referred to
as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on
behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects
of the services to be provided and performed under this Agreement. In each Work Order
CONSULTANT will designate a qualified licensed professional to serve as CONSULTANT's
project coordinator for the Services to be provided under that Work Order (hereinafter referred to
as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on
behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects
of the Services to be provided and performed under the Work Order. Further, the Project
Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of
or relating to the Work Order. The CONSULTANT agrees that the Principal in Charge and the
Project Coordinators shall devote whatever time is required to satisfactorily manage the services
to be provided and performed by the CONSULTANT under the Work Order. CONSULTANT
further agrees that the Principal in Charge and Project Coordinators shall not be removed by
CONSULTANT without the COUNTY's prior written approval, and if so removed must be
immediately replaced with a person acceptable to the COUNTY.
1.13. The CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written
request from the COUNTY to promptly remove and replace the Project Coordinator, or any other
personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors
or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT
to provide and perform services or work pursuant to the requirements of this Agreement, or any
applicable Work Order, said request may be made with or without cause. Any personnel so
removed must be immediately replaced with a person acceptable to the COUNTY.
1.14. The CONSULTANT represents to the COUNTY that it has expertise in the type of
professional services that will be performed pursuant to this Agreement and has extensive
experience with projects similar to the Project required hereunder. The CONSULTANT agrees
that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to
the COUNTY's review and approval and shall be in accordance with the generally accepted
standards of professional practice in the State of Florida, as well as in accordance with all
applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and
requirements of any governmental agencies, and the Florida Building Code where applicable,
which regulate or have jurisdiction over the Services to be provided and performed by
CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76
F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those
contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF
CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE
CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
Page 4 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
The Contractor must specifically comply with the Florida Public Records Law to:
1. Keep and maintain public records required by the public agency to perform the
service.
2. Upon request from the public agency's custodian of public records, provide the
public agency with a copy of the requested records or allow the records to be
inspected or copied within a reasonable time at a cost that does not exceed the cost
provided in this chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for
the duration of the contract term and following completion of the contract if the
Contractor does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records
required by the public agency to perform the service. If the Contractor transfers all
public records to the public agency upon completion of the contract, the Contractor
shall destroy any duplicate public records that are exempt or confidential and
exempt from public records disclosure requirements. If the Contractor keeps and
maintains public records upon completion of the contract, the Contractor shall meet
all applicable requirements for retaining public records. All records stored
electronically must be provided to the public agency, upon request from the public
agency's custodian of public records, in a format that is compatible with the
information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the COUNTY in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the COUNTY shall have the discretion to
unilaterally terminate this Agreement immediately.
1.15. In the event of any conflicts in these requirements, the CONSULTANT shall notify the
COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY
regarding resolution of each such conflict. The COUNTY's approval of the design documents in
no way relieves CONSULTANT of its obligation to deliver complete and accurate documents
necessary for successful construction of the Project.
1.16. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount
for the following: Tasks not completed within the expressed time frame, including required
deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or
federal requirements and/or codes and ordinances applicable to CONSULTANT's performance
of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY
reserves the right to make sole determination regarding deductions. After notification of
deficiency, if the CONSULTANT fails to correct the deficiency within the specified timeframe,
these funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge
the CONSULTANT for services and/or items necessary to correct the deficiencies directly related
to the CONSULTANT's non-performance whether or not the COUNTY obtained substitute
performance.
Page 5 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
1.17. The CONSULTANT agrees not to divulge, furnish or make available to any third person,
firm or organization, without the COUNTY's prior written consent, or unless incident to the proper
performance of the CONSULTANT's obligations hereunder, or in the course of judicial or
legislative proceedings where such information has been properly subpoenaed, any non-public
information concerning the services to be rendered by CONSULTANT hereunder, and
CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to
comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt
written notice of any such subpoenas.
1.18. As directed by the COUNTY, all plans and drawings referencing a specific geographic area
must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in
the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should
either reference specific established Survey Monumentation, such as Certified Section Corners
(Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK (Real -
Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have
common naming conventions (i.e. right-of-way - ROW, centerlines - CL, edge -of -pavement - EOP,
etc.), and adhere to industry standard CAD specifications.
ARTICLE TWO
ADDITIONAL SERVICES OF CONSULTANT
2.1. If authorized in writing by the COUNTY through an Amendment or Change Order to a Work
Order, CONSULTANT shall furnish or obtain from others Additional Services beyond those
Services originally authorized in the Work Order. The agreed upon scope, compensation and
schedule for Additional Services shall be set forth in the Amendment or Change Order authorizing
those Additional Services. With respect to the individuals with authority to authorize Additional
Services under this Agreement, such authority will be as established in the COUNTY's
Procurement Ordinance and Procedures in effect at the time such services are authorized.
Except in an emergency endangering life or property, any Additional Services must be approved
in writing via an Amendment or Change Order to the subject Work Order prior to starting such
services. The COUNTY will not be responsible for the costs of Additional Services commenced
without such express prior written approval. Failure to obtain such prior written approval for
Additional Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional
Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part
of the Services originally required of CONSULTANT under the subject Work Order.
2.2. If the COUNTY determines that a change in a Work Order is required because of the action
taken by CONSULTANT in response to an emergency, an Amendment or Change Order shall be
issued to document the consequences of the changes or variations, provided that CONSULTANT
has delivered written notice to the COUNTY of the emergency within forty-eight (48) hours from
when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-
eight (48) hour written notice noted above, waives CONSULTANT's right it otherwise may have
had to seek an adjustment to its compensation or time of performance under the subject Work
Order.
Page 6 of 33
PSA Fixed Tenn Continuing Contract 2017.009 Ver.2
ARTICLE THREE
THE COUNTY'S RESPONSIBILITIES
3.1. The COUNTY shall designate in writing a project manager to act as the COUNTY's
representative with respect to the services to be rendered under this Agreement (hereinafter
referred to as the "Project Manager"). The Project Manager shall have authority to transmit
instructions, receive information, interpret and define the COUNTY's policies and decisions with
respect to CONSULTANT's services for the Project. However, the Project Manager is not
authorized to issue any verbal or written orders or instructions to the CONSULTANT that would
have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever:
a. The scope of services to be provided and performed by the CONSULTANT as set forth
in the Work Order;
b. The time the CONSULTANT is obligated to commence and complete all such services
as set forth in the Work Order; or
c. The amount of compensation the COUNTY is obligated or committed to pay the
CONSULTANT as set forth in the Work Order.
3.2. The Project Manager shall:
a. Review and make appropriate recommendations on all requests submitted by the
CONSULTANT for payment for services and work provided and performed in
accordance with this Agreement;
b. Provide all criteria and information requested by CONSULTANT as to the COUNTY's
requirements for the Services specified in the Work Order, including design objectives
and constraints, space, capacity and performance requirements, flexibility and
expandability, and any budgetary limitations;
c. Upon request from CONSULTANT, assist CONSULTANT by placing at
CONSULTANT's disposal all available information in the COUNTY's possession
pertinent to the Services specified in the Work Order, including existing drawings,
specifications, shop drawings, product literature, previous reports and any other data
relative to the subject Work Order;
d. Arrange for access to and make all provisions for CONSULTANT to enter the site (if
any) set forth in the Work Order to perform the Services to be provided by
CONSULTANT under the subject Work Order; and
e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the
COUNTY with respect to the Services to be rendered by CONSULTANT hereunder.
ARTICLE FOUR
TIME
4.1. Each Work Order will have a time schedule ("Schedule") for the performance of the
Services required under the subject Work Order. Said Schedule shall be in a form and content
satisfactory to the COUNTY. Services to be rendered by CONSULTANT shall be commenced,
Page 7 of 33
PSA Fixed Term Continuing Contract 2017.009 Vert
performed and completed in accordance with the Work Order and the Schedule. Time is of the
essence with respect to the performance of the Services under each Work Order.
4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of the
Services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due
to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of
government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or
lock -outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days
after commencement of such delay, stating the specific cause or causes thereof, or be deemed
to have waived any right which CONSULTANT may have had to request a time extension for that
specific delay.
4.3. Unless otherwise expressly provided in the Work Order, no interruption, interference,
inefficiency, suspension or delay in the commencement or progress of CONSULTANT's Services
from any cause whatsoever, including those for which COUNTY may be responsible in whole or
in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or
additional compensation from the COUNTY. CONSULTANT's sole remedy against the COUNTY
will be the right to seek an extension of time to the Schedule; provided, however, the granting of
any such time extension shall not be a condition precedent to the aforementioned "No Damage
For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well
as claims based on late completion.
4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the
Services to be provided hereunder in a timely manner, in addition to any other rights or remedies
available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold
any and all payments due and owing to the CONSULTANT under this Agreement (including any
and all Work Orders) until such time as the CONSULTANT resumes performance of its obligations
hereunder in such a manner so as to reasonably establish to the COUNTY's satisfaction that the
CONSULTANT's performance is or will shortly be back on schedule.
4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue
performing Work under any particular Work Order or any payment issued by the COUNTY to
CONSULTANT be deemed a waiver of any right or claim the COUNTY may have against
CONSULTANT for delay or any other damages hereunder.
4.6. The period of service shall be from the date of execution of this Agreement through
five (5 ) year(s) from that date, or until such time as all outstanding Work Orders issued
prior to the expiration of the Agreement period have been completed. The COUNTY may, at its
discretion and with the consent of the CONSULTANT, renew the Agreement under all of the terms
and conditions contained in this Agreement for one (1 ) additional one (1 )
year(s) periods. The COUNTY shall give the CONSULTANT written notice of the COUNTY's
intention to renew the Agreement term prior to the end of the Agreement term then in effect.
4.7. The County Manager, or his designee, may, at his discretion, extend the Agreement under
all of the terms and conditions contained in this Agreement for up to one hundred and eighty (180)
days. The County Manager, or his designee, shall give the CONSULTANT written notice of the
COUNTY's intention to extend the Agreement term prior to the end of the Agreement term then
in effect.
Page 8 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
ARTICLE FIVE
COMPENSATION
5.1. Compensation and the manner of payment of such compensation by the COUNTY for
Services rendered hereunder by CONSULTANT shall be as prescribed in each Work Order. The
Project Manager, or designee, reserves the right to request proposals from this agreement
utilizing any of the following Price Methodologies:
Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are
transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no
hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction
of the COUNTY's Project Manager before payment for the fixed price contract is authorized.
Time and Materials: The COUNTY agrees to pay the contractor for the amount of labor
time spent by the CONSULTANT's employees and subcontractors to perform the work (number
of hours times hourly rate), and for materials and equipment used in the project (cost of materials
plus the contractor's mark-up). This methodology is generally used in projects in which it is not
possible to accurately estimate the size of the project, or when it is expected that the project
requirements would most likely change. As a general business practice, these contracts include
back-up documentation of costs; invoices would include number of hours worked and billing rate
by position (and not company (or subcontractor) timekeeping or payroll records), material or
equipment invoices, and other reimbursable documentation for the project.
5.2. The hourly rates as set forth and identified in Schedule B, Attachment 1, Rate Schedule,
which is attached hereto, shall apply only to projects procured under the Time and Materials
pricing methodology specified in paragraph 5.1 above. ❑■ Grant Funded: The hourly rates as
set forth and identified in Schedule B, Attachment 1, Rate Schedule, which is attached hereto, are
for purposes of providing estimate(s), as required by the grantor agency.
ARTICLE SIX
OWNERSHIP OF DOCUMENTS
6.1. Upon the completion or termination of each Work Order, as directed by the COUNTY,
CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents,
drawings, notes, tracings, plans, MicroStation orAutoCAD files, specifications, maps, evaluations,
reports and other technical data, other than working papers, prepared or developed by or for
CONSULTANT under the applicable Work Order ("Project Documents"). The COUNTY shall
specify whether the originals or copies of such Project Documents are to be delivered by
CONSULTANT. The CONSULTANT shall be solely responsible for all costs associated with
delivering to the COUNTY the Project Documents. The CONSULTANT, at its own expense, may
retain copies of the Project Documents for its files and internal use.
6.2. Notwithstanding anything in this Agreement to the contrary and without requiring the
COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a
nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use with
respect to the applicable authorized project or task. The CONSULTANT warrants to the COUNTY
that it has full right and authority to grant this license to the COUNTY. Further, CONSULTANT
Page 9 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
consents to the COUNTY's use of the Project Documents to complete the subject project or task
following CONSULTANT's termination for any reason or to perform additions to or remodeling,
replacement or renovations of the subject project or task. The CONSULTANT also acknowledges
the COUNTY may be making Project Documents available for review and information to various
third parties and hereby consents to such use by the COUNTY.
ARTICLE SEVEN
MAINTENANCE OF RECORDS
7.1. The CONSULTANT will keep adequate records and supporting documentation which
concern or reflect its services hereunder. The records and documentation will be retained by
CONSULTANT for a minimum of five (5) years from (a) the date of termination this Agreement or
(b) the date of the Work Order is completed, whichever is later, or such later date as may be
required by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY,
shall, free of charge, have the right to audit, inspect and copy all such records and documentation
as often as they deem necessary during the period of this Agreement and during the five (5) year
period noted above, or such later date as may be required by law; provided, however, such activity
shall be conducted only during normal business hours.
ARTICLE EIGHT
INDEMNIFICATION
8.1. To the maximum extent permitted by Florida law, CONSULTANT shall defend, indemnify
and hold harmless the COUNTY, its officers and employees from any and all liabilities, damages,
losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to
the extent caused by the negligence, recklessness, or intentionally wrongful conduct of
CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this
Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce
any other rights or remedies which otherwise may be available to an indemnified party or person
described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
8.1.1. The duty to defend under this Article 8 is independent and separate from the duty
to indemnify, and the duty to defend exists regardless of any ultimate liability of the
CONSULTANT, the COUNTY and any indemnified party. The duty to defend arises immediately
upon presentation of a claim by any party and written notice of such claim being provided to
CONSULTANT. The CONSULTANT's obligation to indemnify and defend under this Article 8 will
survive the expiration or earlier termination of this Agreement until it is determined by final
judgment that an action against the COUNTY or an indemnified party for the matter indemnified
hereunder is fully and finally barred by the applicable statute of limitations.
8.1.2 To the extent that the Agreement that the work pertains to is a "Professional Services
Contract" as defined in Section 725.08(3), Florida Statues, and the CONSULTANT is a "Design
Professional" as defined in Section 725.08(4), Florida Statues, the indemnification provided herein
shall be limited as provided in Section 725.08(1) & (2), Florida Statues.
Page 10 of 33
PSA Fixed Term Continuing Contract 2017,009 Ver.2
ARTICLE NINE
INSURANCE
9.1. The CONSULTANT shall obtain and carry, at all times during its performance under the
Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE C to this
Agreement.
9.2. All insurance shall be from responsible companies duly authorized to do business in the
State of Florida.
9.3. All insurance policies required by this Agreement shall include the following provisions
and conditions by endorsement to the policies:
9.3.1. All insurance policies, other than the Business Automobile policy, Professional
Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the
requirements of this Agreement shall name Collier County Board of County Commissioners, OR,
Board of County Commissioners in Collier County, OR, Collier County Government, as an
additional insured as to the operations of CONSULTANT under this Agreement and shall contain
a severability of interests' provisions.
9.3.2. Companies issuing the insurance policy or policies shall have no recourse against
the COUNTY for payment of premiums or assessments for any deductibles which all are at the
sole responsibility and risk of CONSULTANT.
9.3.3. All insurance coverages of CONSULTANT shall be primary to any insurance or self-
insurance program carried by the COUNTY, and the "Other Insurance" provisions of any policies
obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by
COUNTY.
9.3.4. The Certificates of Insurance, which are to be provided in an Occurrence Form
patterned after the current I.S.O. form with no limiting endorsements, must reference and identify
this Agreement.
9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall
be construed in accordance with the laws of the State of Florida.
9.4. The CONSULTANT, its subconsultants and the COUNTY shall waive all rights against
each other for damages covered by insurance to the extent insurance proceeds are paid and
received by the COUNTY, except such rights as they may have to the proceeds of such insurance
held by any of them.
9.5. All insurance companies from whom CONSULTANT obtains the insurance policies
required hereunder must meet the following minimum requirements:
9.5.1. The insurance company must be duly licensed and authorized by the Department
of Insurance of the State of Florida to transact the appropriate insurance business in the State of
Florida.
9.5.2. The insurance company must have a current A. M. Best financial rating of "Class
VI" or higher.
Page 11 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
ARTICLE TEN
SERVICES BY CONSULTANT'S OWN STAFF
10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff,
unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use
of the services of any other person or firm by CONSULTANT, as independent consultant or
otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this
Agreement shall, however, be construed as constituting an agreement between the COUNTY and
any such other person or firm. Nor shall anything in this Agreement be deemed to give any such
party or any third party any claim or right of action against the COUNTY beyond such as may then
otherwise exist without regard to this Agreement.
10.2. Attached to each Work Order shall be a Schedule that lists all of the key personnel
CONSULTANT intends to assign to perform the Services required under that Work Order. Such
personnel shall be committed to the project or task specified in the Work in accordance with the
percentages noted in the attached schedule. CONSULTANT shall also identify in that Schedule
each subconsultant and subcontractor it intends to utilize with respect to the subject Work Order.
All personnel, subconsultants and subcontractors identified in the Schedule shall not be removed
or replaced without the COUNTY's prior written consent.
10.3. The CONSULTANT is liable for all the acts or omissions of its subconsultants or
subcontractors. By appropriate written agreement, the CONSULTANT shall require each
subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant
or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement and any
subsequently issued Work Order, and to assume toward the CONSULTANT all the obligations
and responsibilities which the CONSULTANT, by this Agreement and any subsequently issued
Work Order, assumes toward the COUNTY. Each subconsultant or subcontract agreement shall
preserve and protect the rights of the COUNTY under this Agreement, and any subsequently
issued Work Order, with respect to the Services to be performed by the subconsultant or
subcontractor so that the subconsulting or subcontracting thereof will not prejudice such rights.
Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter
into similar agreements with its sub-subconsultants or sub -subcontractors.
10.4. The CONSULTANT acknowledges and agrees that the COUNTY is a third -party
beneficiary of each contract entered into between CONSULTANT and each subconsultant or
subcontractor, however nothing in this Agreement shall be construed to create any contractual
relationship between the COUNTY and any subconsultant or subcontractor. Further, all such
contracts shall provide that, at the COUNTY's discretion, they are assignable to the COUNTY
upon any termination of this Agreement.
ARTICLE ELEVEN
WAIVER OF CLAIMS
11.1. The CONSULTANT's acceptance of final payment for Services provided under any Work
Order shall constitute a full waiver of any and all claims, except for insurance company
subrogation claims, by it against the COUNTY arising out of the Work Order or otherwise related
to those Services, and except those previously made in writing in accordance with the terms of
this Agreement and identified by CONSULTANT in its final invoice for the subject Work Order as
Page 12 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
unsettled. Neither the acceptance of CONSULTANT's Services nor payment by the COUNTY
shall be deemed to be a waiver of any of COUNTY's rights against CONSULTANT.
ARTICLE TWELVE
TERMINATION OR SUSPENSION
12.1. This Agreement is a fixed term contract for the professional services of CONSULTANT. It
is agreed that either party hereto shall at any and all times have the right and option to terminate
this Agreement by giving to the other party not less than thirty (30) days prior written notice of
such termination. Upon this Agreement being so terminated by either party hereto, neither party
hereto shall have any further rights or obligations under this Agreement subsequent to the date
of termination, except that Services specified to be performed under a previously issued Work
Order, shall proceed to completion under the terms of this Agreement.
12.2. The CONSULTANT shall be considered in material default of this Agreement and such
default will be considered cause for the COUNTY to terminate this Agreement and any Work
Orders in effect, in whole or in part, as further set forth in this section, for any of the following
reasons: (a) CONSULTANT's failure to begin Services under any particular Work Order within
the times specified under that Work Order, or (b) CONSULTANT's failure to properly and timely
perform the Services to be provided hereunder or as directed by the COUNTY, or (c) the
bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT
or by any of CONSULTANT's principals, officers or directors, or (d) CONSULTANT's failure to
obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT's failure
to perform or abide by the terms and conditions of this Agreement and any Work Orders in effect,
or (f) for any other just cause. The COUNTY may so terminate this Agreement and any Work
Orders in effect, in whole or in part, by giving the CONSULTANT seven (7) calendar days written
notice of the material default.
12.3. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it
is determined for any reason that CONSULTANT was not in default, or that its default was
excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT
provided for in paragraph 12.2, then the notice of termination given pursuant to paragraph 12.2
shall be deemed to be the notice of termination provided for in paragraph 12.4, below, and
CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those
afforded CONSULTANT under paragraph 12.4 below.
12.4. Notwithstanding anything herein to the contrary (including the provisions of paragraph 12.1
above), the COUNTY shall have the right to terminate this Agreement and any Work Orders in
effect, in whole or in part, without cause upon seven (7) calendar days written notice to
CONSULTANT. In the event of such termination for convenience, CONSULTANT's recovery
against the COUNTY shall be limited to that portion of the fee earned through the date of
termination, for any Work Orders so cancelled, together with any retainage withheld and any costs
reasonably incurred by CONSULTANT that are directly attributable to the termination, but
CONSULTANT shall not be entitled to any other or further recovery against the COUNTY,
including, but not limited to, anticipated fees or profits on Services not required to be performed.
CONSULTANT must mitigate all such costs to the greatest extent reasonably possible.
12.5. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the
COUNTY all original papers, records, documents, drawings, models, and other material set forth
Page 13 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
and described in this Agreement, including those described in Article 6, that are in
CONSULTANT's possession or under its control arising out of or relating to this Agreement or any
Work Orders.
12.6. The COUNTY shall have the power to suspend all or any portions of the Services to be
provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior
written notice of such suspension. If all or any portion of the Services to be rendered hereunder
are so suspended, the CONSULTANT's sole and exclusive remedy shall be to seek an extension
of time to its schedule in accordance with the procedures set forth in Article Four herein.
12.7. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT
within forty-five (45) days after such payment is due as set forth in the Work Order or such other
time as required by Florida's Prompt Payment Act or (ii) the COUNTY otherwise persistently fails
to fulfill some material obligation owed by the COUNTY to CONSULTANT under this Agreement
or subsequently issued Work Order, and (ii) the COUNTY has failed to cure such default within
fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT
may stop its performance under the subject Work Order until such default is cured, after giving
the COUNTY a second fourteen (14) days written notice of CONSULTANT's intention to stop
performance under the applicable Work Order. If the Services are so stopped for a period of one
hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its
subconsultant or subcontractor or their agents or employees or any other persons performing
portions of the Services under contract with the CONSULTANT, the CONSULTANT may
terminate the subject Work Order by giving written notice to the COUNTY of CONSULTANT's
intent to terminate that Work Order. If the COUNTY does not cure its default within fourteen (14)
days after receipt of CONSULTANT's written notice, CONSULTANT may, upon fourteen (14)
additional days' written notice to the COUNTY, terminate the subject Work Order and recover
from the COUNTY payment for Services performed through the termination date, but in no event
shall CONSULTANT be entitled to payment for Services not performed or any other damages
from the COUNTY.
ARTICLE THIRTEEN
TRUTH IN NEGOTIATION REPRESENTATIONS
13.1. The CONSULTANT warrants that CONSULTANT has not employed or retained any
company or person, other than a bona fide employee working solely for CONSULTANT, to solicit
or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person,
company, corporation, individual or firm, other than a bona fide employee working solely for
CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon
or resulting from the award or making of this Agreement or any subsequent Work Order.
13.2. 0 CCNA Projects: In accordance with provisions of Section 287.055, (5)(a), Florida
Statutes, the CONSULTANT agrees to execute the required Truth -In -Negotiation Certificate,
attached hereto and incorporated herein as Schedule D, certifying that wage rates and other
factual unit costs supporting the compensation for CONSULTANT's services to be provided under
this Agreement and each subsequent Work Order issued hereafter, if any, are accurate, complete
and current at the time of the Agreement or such subsequent Work Order. The CONSULTANT
agrees that the original price as set forth in each subsequent issued Work Order, if any, and any
additions thereto shall be adjusted to exclude any significant sums by which the COUNTY
determines the price as set forth in the Work Order was increased due to inaccurate, incomplete,
Page 14 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
or non -current wage rates and other factual unit costs. All such adjustments shall be made within
one (1) year following the end of the subject Work Order.
ARTICLE FOURTEEN
CONFLICT OF INTEREST
14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest,
either direct or indirect, which would conflict in any manner with the performance of services
required hereunder. CONSULTANT further represents that no persons having any such interest
shall be employed to perform those services.
ARTICLE FIFTEEN
MODIFICATION
15.1. No modification or change in this Agreement shall be valid or binding upon either party
unless in writing and executed by the party or parties intended to be bound by it.
15.2. In the event that the need for changes to the Services under a Work Order may arise
during the course of the work, the associated tasks may be modified at the request of the Project
Manager or his designee. Written authorization from the Project Manager will be required in
accordance with the Procurement Ordinance, as amended, and Procedures. For any changes
that exceed an existing Work Order amount, the Work Order shall be modified to reflect the
increase prior to any related Services being performed.
15.3. All duly executed modifications to Work Orders (including all written modifications or
Changes thereto) are hereby incorporated into and made a part of this Agreement by reference.
ARTICLE SIXTEEN
NOTICES AND ADDRESS OF RECORD
16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT
to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
the COUNTY's address of record:
Board of County Commissioners for Collier County, Florida
Division Name: Procurement Services Division
Division Director: Sandra Herrera
Address: 3295 Tamiami Trail East
Naples, Florida 34112-4901
Administrative Agent/PM: Evelyn Colon
Telephone: (239) 252-2667
E-Mail(s): Evelyn.Colon@colliercountyfl.gov
Page 15 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to
the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United
States Postal Service Department, first class mail service, postage prepaid, addressed to the
following CONSULTANT's address of record:
Company Name:
Address:
Authorized Agent:
Attention Name & Title:
Telephone:
E-Mail(s):
Cribb Philbeck Weaver Group, Inc.
1221 E Broadwav Street. Suite 1031
Oviedo. Florida 32765
Sheila Tarte, President
(813) 361-2644
sheila.tarte@cpwgengineering.com
16.3. Either party may change its address of record by written notice to the other party given in
accordance with requirements of this Article.
ARTICLE SEVENTEEN
MISCELLANEOUS
17.1. The CONSULTANT, in representing the COUNTY, shall promote the best interests of the
COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair
dealing.
17.2. No modification, waiver, suspension or termination of the Agreement or of any terms
thereof shall impair the rights or liabilities of either party.
17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by
CONSULTANT without the orior written consent of the COUNTY.
17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed
to be a waiver of any other breach and shall not be construed to be a modification of the terms of
this Agreement.
17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this
Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or
change the provisions in such Articles, Schedules, Parts and Attachments.
17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes
the entire agreement between the parties hereto and shall supersede, replace and nullify any and
all prior agreements or understandings, written or oral, relating to the matter set forth herein, and
any such prior agreements or understanding shall have no force or effect whatever on this
Agreement.
17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties
shall survive the expiration or termination of this Agreement.
Page 16 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
17.8. This Agreement may be simultaneously executed in several counterparts, each of which
shall be an original and all of which shall constitute but one and the same instrument.
17.9. The terms and conditions of the following Schedules attached hereto are by this reference
incorporated herein:
Schedule A
Schedule B
Schedule C
Schedule D
Schedule E
Solicitation #
WORK ORDER
RATE SCHEDULE
INSURANCE
CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE
Other: N/A
18-7432-LA including all Attachment(s), Exhibit(s) and
Addendum/Consultant's Proposal
17.10. 0 Grant Funded Projects: In the event of any conflict between or among the terms of
any of the Contract Documents and/or the COUNTY's Board approved Executive Summary, the
terms of the Agreement shall take precedence over the terms of all other Contract Documents,
except the terms of any Supplemental Grant Conditions shall take precedence over the
Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved
by application of the Supplemental Conditions, if any, or the Agreement, the conflict shall be
resolved by imposing the more strict or costly obligation under the Contract Documents upon the
CONSULTANT at the COUNTY's discretion.
17.11. Applicability. Sections corresponding to any checked box expressly apply to the
terms of this Agreement.
ARTICLE EIGHTEEN
APPLICABLE LAW
18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of
Florida, and by such laws, rules and regulations of the United States as made applicable to
services funded by the United States government. Any suit or action brought by either party to
this Agreement against the other party relating to or arising out of this Agreement must be brought
in the appropriate federal or state courts in Collier County, Florida, which courts have sole and
exclusive jurisdiction on all such matters.
ARTICLE NINETEEN
SECURING AGREEMENT/PUBLIC ENTITY CRIMES
19.1. The CONSULTANT warrants that CONSULTANT has not employed or retained any
company or person, other than a bona fide employee working solely for CONSULTANT, to solicit
or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person,
company, corporation, individual or firm, other than a bona fide employee working solely for
CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon
or resulting from the award or making of this Agreement. ❑E At the time this Agreement is
executed, CONSULTANT shall sign and deliver to the COUNTY the Truth -In -Negotiation
Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule D.
The CONSULTANT's compensation as set forth in each subsequently issued Work Order, if any,
Page 17 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
shall be adjusted to exclude any sums by which the COUNTY determines the compensation was
increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs.
19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed
by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida
Statutes which read as follows:
"A person or affiliate who has been placed on the convicted vendor list following
a conviction for a public entity crime may not submit a bid, proposal, or reply on
a contract to provide any goods or services to a public entity, may not submit a
bid, proposal, or reply on a contract with a public entity for the construction or
repair of a public building or public work; may not submit bids, proposals, or
replies on leases of real property to a public entity, may not be awarded or
perform work as a contractor, supplier, subcontractor, or consultant under a
contract with any public entity; and may not transact business with any public
entity in excess of the threshold amount provided in s. 287.017 for CATEGORY
TWO for a period of 36 months following the date of being placed on the
convicted vendor list."
ARTICLE TWENTY
DISPUTE RESOLUTION
20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any such
disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT
with full decision -making authority and by the COUNTY's staff person who would make the
presentation of any settlement reached during negotiations to the COUNTY for approval. Failing
resolution, and prior to the commencement of depositions in any litigation between the parties
arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation
before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation
shall be attended by representatives of CONSULTANT with full decision -making authority and by
the COUNTY's staff person who would make the presentation of any settlement reached at
mediation to the COUNTY's board for approval. Should either party fail to submit to mediation as
required hereunder, the other party may obtain a court order requiring mediation under section
44.102, Fla. Stat.
20.2. Any suit or action brought by either party to this Agreement against the other party relating
to or arising out of this Agreement must be brought in the appropriate federal or state courts in
Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters.
ARTICLE TWENTY-ONE
IMMIGRATION LAW COMPLIANCE
21.1. By executing and entering into this agreement, the CONSULTANT is formally
acknowledging without exception or stipulation that it is fully responsible for complying with the
provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq.
and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to
Page 18 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
comply with the laws referenced herein shall constitute a breach of this agreement and the
COUNTY shall have the discretion to unilaterally terminate this Agreement immediately.
(signature page to follow)
Page 19 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
IN WITNESS WHEREOF, the parties hereto have executed this Professional Services
Agreement the day and year first written above.
ATTEST:
Crystal K. Kinzel. Clerk of Court &
Comptrolvn)
�r
By
Date:
AtteslO
signature only.
App�o4ed as to FAm anti Legality
bepm County Attorney
Name
A
Consultant's Witnesses: n?\
BOARD OF COUNTY COMMISSIONERS FOR
COLLIER COUNTY, FLORIDA,
Burt L. Saunders
Consultant:
Chairman
Cribb Philbeck Weaver Group, Inc.
Ac'AJmfA, '— By:
Itness
chAe,l M. B rb4
Name and Title Name and Title
l
Witness
Sess
Name and Title
Page 20 ol'33
1'tiA I ts:cl lrrm ( untunuu:r. C wllla t �;, .- - w GCf
0
SCHEDULE A
WORK ORDER
Contract 00-0000 "Name of Contract'
Contract Expiration Date: , 20
This Work Order is for professional (describe) services for work known as:
Project Name:
Project No:
The work is specified in the proposal dated , 20 which is attached hereto and made a part of this Work Order. In
accordance with Terms and Conditions of the Agreement referenced above, this Work Order is assigned to: Name of Firm
Scope of Work: As detailed in the attached proposal and the following:
* Task I -
* Task II
* Task III
Schedule of Work: Complete work within days from the date of the Notice to Proceed which is accompanying this Work
Order. The Consultant agrees that any Work Order that extends beyond the expiration date of Agreement # 00-0000 will survive
and remain subject to the terms and conditions of that Agreement until the completion or termination of this Work Order.
Compensation: In accordance with the Agreement referenced above, the County will compensate the Firm in accordance with
following method(s): ❑Negotiated Lump Sum (NLS) ❑Lump Sum Plus Reimbursable Costs (LS+RC) ❑Time & Material
(T&M) (established hourly rate — Schedule A) ❑Cost Plus Fixed Fee (CPFF), (define which method will be used for which
tasks) as provided in the attached proposal.
Task 1
Task II
Task III
TOTAL FEE
PREPARED BY: _
Name and Title Date
APPROVED BY:
(Dept Name) , Division Director Date
APPROVED BY:
type name, Department Head Date
By the signature below, the Firm (including employees, officers and/or agents) certifies, and hereby discloses, that, to the best of their knowledge and belief, all
relevant facts concerning past, present, or currently planned interest or activity (financial, contractual, organizational, or otherwise) which relates to the proposed
work; and bear on whether the Firm has a potential conflict have been fully disclosed.
Additionally, the Firm agrees to notify the Procurement Director, in writing within 48 hours of learning of any actual or potential conflict of interest that arises
during the Work Order and/or project duration.
ACCEPTED BY: (Firm Name)
Name & Title of Authorized Officer Date
Page 21 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
SCHEDULE B
BASIS OF COMPENSTATION
1. SERVICES
B.1.1. As the COUNTY identifies certain Services it wishes CONSULTANT to provide pursuant
to the terms of this Agreement, the COUNTY shall request a proposal from CONSULTANT for
such Services, said proposal to be in compliance with the terms of this Agreement. If the parties
reach an agreement with respect to such Services, including, but not limited to the scope,
compensation and schedule for performance of those Services, a Work Order shall be issued
which incorporates the terms of the understanding reached by the parties with respect to such
Services.
B.1.1.1. The COUNTY may request that CONSULTANT in writing advise the COUNTY of
(i) the estimated time of CONSULTANT's personnel and the estimated fees thereof for the
proposed work to be specified in the Work Order; and (ii) the estimated charge to the COUNTY
for the reimbursable expenses applicable to the contemplated Services to be performed by
CONSULTANT under the proposed Work Order. CONSULTANT shall promptly supply such
estimate to the COUNTY based on CONSULTANT's good faith analysis.
B.1.2. All Services to be performed by CONSULTANT pursuant to this Agreement shall be in
conformance with the scope of services, which shall be described in a Work Order issued pursuant
to the procedures described herein. Reference to the term Work Order herein, with respect to
authorization of Services, includes all written Work Order Modifications or Amendments.
B.1.3. All Services must be authorized in writing by the COUNTY in the form of a Work Order.
CONSULTANT shall not provide any Services to the COUNTY unless and to the extent they are
required in a written Work Order. Any Services provided by CONSULTANT without a written
Work Order shall be at CONSULTANT's own risk and the COUNTY shall have no liability for such
Services.
B.1.4. Upon issuance of a Work Order as aforesaid, CONSULTANT agrees to promptly provide
the Services required thereby, in accordance with the terms of this Agreement and the subject
Work Order.
2. COMPENSATION TO CONSULTANT
B.2.1. Payments for Basic Services and Additional Basic Services as set forth herein or the Work
Order shall be made upon presentation of the CONSULTANT's invoice approved by the
COUNTY.
B.2.2. Payments will be made for services furnished, delivered, and accepted, upon receipt and
approval of invoices submitted on the date of services or within six (6) months after completion of
contract. Any untimely submission of invoices beyond the specified deadline period is subject to
non-payment under the legal doctrine of 1aches" as untimely submitted. Time shall be deemed of
the essence with respect to the timely submission of invoices under this Agreement.
Page 22 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
B.2.3. For the Services provided for in this Agreement, the COUNTY agrees to make payments
to CONSULTANT based upon CONSULTANT's Direct Labor Costs and Reimbursable Expenses
or as a Lump Sum.
B.2.4. ■❑ Time and Material Fees: Direct Labor Costs mean the actual salaries and wages (basic,
premium and incentive) paid to CONSULTANT's personnel, with respect to this Agreement,
including all indirect payroll related costs and fringe benefits, all in accordance with and not in
excess of the rates set forth in the Attachment 1 to this Schedule B. With each monthly
Application for Payment, CONSULTANT shall submit detailed time records, and any other
documentation reasonably required by the COUNTY, regarding CONSULTANT's Direct Labor
Costs incurred at the time of billing, to be reviewed and approved by the COUNTY. There shall
be no overtime pay without the COUNTY's prior written approval.
B.2.4.1. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the
COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based
on the services to be provided and as set forth in the Amendment authorizing such Additional
Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this
Schedule B and all Reimbursable Expenses shall comply with the provision of Section B.3.4.1
below. There shall be no overtime pay on Additional Services without the COUNTY's prior written
approval.
B.2.4.2. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's
monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable
not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has
completed such task as of that particular monthly billing.
B.2.5. ❑■ Lump Sum Fees: The fees noted in the Work Order shall constitute the lump sum
amount to be paid to CONSULTANT for the performance of the Services. CONSULTANT shall
submit to the COUNTY as part of its monthly invoice a progress report reflecting the status, in
terms of the total work effort estimated to be required for the completion of the Services authorized
under the Work Order and any then -authorized Additional Services, as of the last day of the
subject monthly billing cycle. Among other things, the report shall show all Service items and the
percentage complete of each item. There shall be no overtime pay without the COUNTY's prior
written approval.
B.2.6. For Additional Services provided pursuant to Article 2 of the Agreement, the COUNTY
agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the
services to be provided and as set forth in the Amendment authorizing such Additional Services.
The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B
and all Reimbursable Expenses shall comply with the provisions of Section 3 below. There shall
be no overtime pay on Services or Additional Services without COUNTY's prior written approval.
B.2.7. Unless specific rates have been established in Attachment 1, attached to this Schedule B,
CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by
CONSULTANT for a particular Work Order or Additional Services, CONSULTANT shall be limited
to a maximum markup of five percent (5%) on the fees and expenses associated with such
subconsultants and subcontractors.
B.2.8. The CONSULTANT agrees to furnish to the COUNTY, after the end of each calendar
month, or as specified in the Work Order, statement of charges for the Services performed and
Page 23 of 33
PSA Fixed Term Continuing Contract 2017,009 Ver.2
rendered by CONSULTANT during that time period, and for any the COUNTY authorized
reimbursable expenses as herein below defined, incurred and/or paid by CONSULTANT during
that time period. The monthly statement shall be in such form and supported by such
documentation as may be required by the COUNTY. Notwithstanding anything herein to the
contrary, the CONSULTANT shall submit no more than one (1) invoice per month for both Basic
Services and Additional Services. Invoices shall be reasonably substantiated, identify the
services rendered and must be submitted in a form and manner required by the COUNTY.
B.2.9. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done,
no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted
on CONSULTANT's letterhead and must include the Purchase Order Number and Project name
and shall not be submitted more than one time monthly.
B.2.10. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges
and agrees that in the event of a dispute concerning payments for Services performed under this
Agreement, CONSULTANT shall continue to perform the Services required of it under this
Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the
COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are
due and payable.
3. REIMBURSABLE EXPENSES
B.3.1. Payments for Additional Services of CONSULTANT as defined in Section 2 hereinabove
and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with
supporting documentation.
B.3.2. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring
any reimbursable expenses, and absent such prior approval, no expenses incurred by
CONSULTANT will be deemed to be a reimbursable expense.
B.3.3. The COUNTY agrees to reimburse CONSULTANT for all necessary and reasonable
reimbursable expenses incurred or paid by CONSULTANT in connection with CONSULTANT's
performance of the Services, at its direct cost with no markup; to the extent such reimbursement
is permitted in the Work Order and in accordance with Section 112.061, F.S., or as set forth in
this Agreement. Reimbursable expenses shall be invoiced for the expenditures incurred by the
CONSULTANT as stated below.
5.3.3.1. Cost for reproducing documents that exceed the number of documents described
in this Agreement and postage and handling of Drawings and Specifications including duplicate
sets at the completion of each Work Order for the COUNTY's review and approval.
5.3.3.2. Travel expenses reasonably and necessarily incurred with respect to Project
related trips, to the extent such trips are approved by the COUNTY. Such expenses, if approved
by the COUNTY, may include coach airfare, standard accommodations and meals, all in
accordance with Section 112.061, F.S. Further, such expenses, if approved by the COUNTY, may
include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such
trips within Collier and Lee Counties are expressly excluded.
5.3.3.3. Expense of overtime work requiring higher than regular rates approved in advance
and in writing by the COUNTY.
Page 24 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
5.3.3.4. Permit Fees required by the Project.
5.3.3.5. Expense of models for the COUNTY's use.
5.3.3.6. Fees paid for securing approval of authorities having jurisdiction over the Work
Order required under the applicable Work Order.
5.3.3.7. Other items on request and approved in writing by the COUNTY.
5.3.4. The CONSULTANT shall bear and pay all overhead and other expenses, except for
authorized reimbursable expenses, incurred by CONSULTANT in the performance of the
Services.
5.3.5. Records of Reimbursable Expenses shall be kept on a generally recognized accounting
basis.
Page 25 of 33
PSA Fixed Term Continuing Contract 2017,009 Ver.2
SCHEDULE B - ATTACHMENT 1
RATE SCHEDULE
Title Hourly Rate
Principal/ Sr. Landscape Architect $165
Landscape Architect $140
Design Associate $130
AutoCAD Technician $95
Administrative/ Clerical $70
The above hourly rates are applicable to Time and Materials task(s) only. The above list may not
be all inclusive. Hourly rates for additional categories required to provide particular project
services shall be mutually agreed upon by the County and firm, in writing, on a project by project
basis, as needed, and will be set forth in the Work Order agreed upon by the parties.
■❑ Grant Funded: The above hourly rates are for purposes of providing estimate(s), as required
by the grantor agency.
Page 26 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
SCHEDULE C
INSURANCE COVERAGE
1. The amounts and types of insurance coverage shall conform to the following minimum
requirements with the use of Insurance Services Office (ISO) forms and endorsements or their
equivalents. If CONSULTANT has any self -insured retentions or deductibles under any of the
below listed minimum required coverages, CONSULTANT must identify on the Certificate of
Insurance the nature and amount of such self -insured retentions or deductibles and provide
satisfactory evidence of financial responsibility for such obligations. All self -insured retentions or
deductibles will be CONSULTANT's sole responsibility.
2. The insurance required by this Agreement shall be written for not less than the limits
specified herein or required by law, whichever is greater.
3. Coverages shall be maintained without interruption from the date of commencement of the
services until the date of completion and acceptance of the Project by the COUNTY or as specified
in this Agreement, whichever is longer.
4. Certificates of insurance acceptable to the COUNTY shall be filed with the COUNTY within
ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact
that CONSULTANT has acquired and put in place the insurance coverages and limits required
hereunder. In addition, certified, true and exact copies of all insurance policies required shall be
provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall
contain a provision that coverages afforded under the policies will not be canceled or allowed to
expire until at least thirty (30) days prior written notice has been given to the COUNTY.
CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after
receipt, of any notices of expiration, cancellation, non -renewal or material change in coverages or
limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve
CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate
limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately
take steps to have the aggregate limit reinstated to the full extent permitted under such policy.
5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self-
insurance program carried by the COUNTY applicable to this Project.
6. The acceptance by the COUNTY of any Certificate of Insurance does not constitute
approval or agreement by the COUNTY that the insurance requirements have been satisfied or
that the insurance policy shown on the Certificate of Insurance is in compliance with the
requirements of this Agreement.
7. CONSULTANT shall require each of its subconsultants to procure and maintain, until the
completion of the subconsultant's services, insurance of the types and to the limits specified in
this Section except to the extent such insurance requirements for the subconsultant are expressly
waived in writing by the COUNTY.
8. Should at any time the CONSULTANT not maintain the insurance coverages required
herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to
purchase such coverages and charge the CONSULTANT for such coverages purchased. If
CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand,
Page 27 of 33
PSA Fixed Term Continuing Contract 2017,009 Ver.2
the COUNTY has the right to offset these costs from any amount due CONSULTANT under this
Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY
shall be under no obligation to purchase such insurance, nor shall it be responsible for the
coverages purchased or the insurance company or companies used. The decision of the
COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of
any of its rights under the Agreement.
9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the
completion of the services required hereunder or termination of the Agreement, the
CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of
Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the
Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material
breach by CONSULTANT and the COUNTY may terminate the Agreement for cause.
10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY.
Required by this Agreement? ❑■ Yes ❑ No
Workers' Compensation and Employers' Liability Insurance shall be maintained by the
CONSULTANT during the term of this Agreement for all employees engaged in the work under
this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance
shall not be less than:
a. Worker's Compensation - Florida Statutory Requirements
b. Employers' Liability - The coverage must include Employers' Liability with a
minimum limit of $1,000,000 for each accident.
The insurance company shall waive all claims rights against the COUNTY and the policy shall be
so endorsed.
11. United States Longshoreman's and Harbor Worker's Act coverage shall be maintained
where applicable to the completion of the work. Required by this Agreement? ❑ Yes ❑■ No
12. Maritime Coverage (Jones Act) shall be maintained where applicable to the completion
of the work.
Required by this Agreement? ❑ Yes ❑■ No
13. COMMERCIAL GENERAL LIABILITY.
Required by this Agreement? F Yes ❑ No
A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be
maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury,
Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent
Contractors, Broad Form Property Damage including Completed Operations and Products and
Completed Operations Coverage. Products and Completed Operations coverage shall be
Page 28 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
maintained for a period of not less than five (5) years following the completion and acceptance by
the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the
following:
Coverage shall have minimum limits of $1,000,000 Per Occurrence,
$ 2,000,000 aggregate.
B. The General Aggregate Limit shall apply separately to this Project and the policy shall
be endorsed using the following endorsement wording. "This endorsement modifies insurance
provided under the following: Commercial General Liability Coverage Part. The General
Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away
from premises owned by or rented to you." Applicable deductibles or self -insured retentions shall
be the sole responsibility of CONSULTANT. Deductibles or self -insured retentions carried by the
CONSULTANT shall be subject to the approval of the Risk Management Director or his/her
designee.
14. Collier County Board of County Commissioners, OR, Board of County Commissioners in
Collier County, OR, Collier County Government shall be listed as the Certificate Holder and
included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability
where required. The insurance shall be primary and non-contributory with respect to any other
insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's
policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with
the same insurance requirements that the Contractor is required to meet.
15. Watercraft Liability coverage shall be carried by the CONSULTANT or the
SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in
subparagraph (1) above if applicable to the completion of the Services under this Agreement.
Required by this Agreement? ❑ Yes ❑E No
16. Aircraft Liability coverage shall be carried by the CONSULTANT or the
SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the
completion of the Services under this Agreement.
Required by this Agreement? ❑ Yes ❑■ No
17. AUTOMOBILE LIABILITY INSURANCE.
Required by this Agreement? 0 Yes ❑ No
Business Auto Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This
shall include: Owned Vehicles, Hired and Non -Owned Vehicles and Employee Non -The
ownership.
18. TECHNOLOGY ERRORS and OMISSIONS INSURANCE.
Required by this Agreement? ❑ Yes ❑■ No
Page 29 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
Technology Errors and Omissions Insurance: Coverage shall have minimum limits of
$ Per Occurrence.
19. CYBER INSURANCE.
Required by this Agreement? ❑ Yes ❑■ No
Cyber Insurance: Coverage shall have minimum limits of $
20. UMBRELLA LIABILITY.
Per Occurrence.
A. Umbrella Liability may be maintained as part of the liability insurance of the
CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial
General Liability, and Automobile Liability coverages required herein and shall include all
coverages on a "following form" basis.
B. The policy shall contain wording to the effect that, in the event of the exhaustion of any
underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as
primary insurance.
21. PROFESSIONAL LIABILITY INSURANCE.
Required by this Agreement? ❑■ Yes ❑ No
A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its
legal liability for claims arising out of the performance of professional services under this
Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under
this insurance. Such insurance shall have limits of not less than $ 1,000,000 each claim and
aggregate.
B. Any deductible applicable to any claim shall be the sole responsibility of the
CONSULTANT. Deductible amounts are subject to the approval of the COUNTY.
C. The CONSULTANT shall continue this coverage for this Project for a period of not
less than five (5) years following completion and acceptance of the Project by the COUNTY.
D. The policy retroactive date will always be prior to the date services were first
performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the
term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit
Certificates of Insurance providing for an unqualified written notice to the COUNTY of any
cancellation of coverage or reduction in limits, other than the application of the aggregate limits
provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within
twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non -renewal or
material change in coverages or limits received by CONSULTANT from its insurer. In the event
of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT
shall immediately take steps to have the aggregate limit reinstated to the full extent permitted
under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and
any endorsements issued or to be issued on the policy if requested by the COUNTY.
Page 30 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
22. VALUABLE PAPERS INSURANCE.
In the sole discretion of the COUNTY, CONSULTANT may be required to purchase
valuable papers and records coverage for plans, specifications, drawings, reports, maps, books,
blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or
reconstructing valuable papers or records utilized during the term of this Agreement.
23. PROJECT PROFESSIONAL LIABILITY.
A. If the COUNTY notifies CONSULTANT that a project professional liability policy will
be purchased, then CONSULTANT agrees to use its best efforts in cooperation with THE
COUNTY and the COUNTY's insurance representative, to pursue the maximum credit available
from the professional liability carrier for a reduction in the premium of CONSULTANT's
professional liability policy. If no credit is available from CONSULTANT's current professional
policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the
next renewal policy, if a renewal occurs during the term of the project policy (and on any
subsequent professional liability policies that renew during the term of the project policy).
CONSULTANT agrees that any such credit will fully accrue to the COUNTY. Should no credit
accrue to the COUNTY, the COUNTY and CONSULTANT, agree to negotiate in good faith a
credit on behalf of the COUNTY for the provision of project -specific professional liability insurance
policy in consideration for a reduction in CONSULTANT's self -insured retention and the risk of
uninsured or underinsured consultants.
B. The CONSULTANT agrees to provide the following information when requested by
the COUNTY or the COUNTY's Project Manager:
1. The date the professional liability insurance renews.
2. Current policy limits.
3. Current deductibles/self-insured retention.
4. Current underwriter.
5. Amount (in both dollars and percent) the underwriter will give as a credit if the
policy is replaced by an individual project policy.
6. Cost of professional insurance as a percent of revenue.
7. Affirmation that the design firm will complete a timely project errors and omissions
application.
C. If the COUNTY elects to purchase a project professional liability policy,
CONSULTANT to be insured will be notified and the COUNTY will provide professional liability
insurance, naming CONSULTANT and its professional subconsultants as named insureds.
END OF SCHEDULE C
Page 31 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
LE -this schedule is not applicable
SCHEDULE D
TRUTH IN NEGOTIATION CERTIFICATE
In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida
Statutes, Cribb Philbeck Weaver Group, Inc. (company's name)
hereby certifies that wages, rates and other factual unit costs supporting the compensation for the
services of the CONSULTANT to be provided under the Professional Services Agreement,
concerning " Professional Services Library Landscape Architecture Category
project is accurate. complete and current as of the time of contracting.
BY:
TITLE:
DATE:
i'aI c 32 of 33
0
Other:
SCHEDULE E
(Description)
❑ following this page (pages through )
❑■ this schedule is not applicable
Page 33 of 33
PSA Fixed Term Continuing Contract 2017.009 Ver.2
A/^40RIDO 0 DATE (MM/DDIYYYY)
CERTIFICATE OF LIABILITY INSURANCE 04/09/2020
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER CONTACT Tammy y H yder
Talbert Insurance Services PHONE., (770)497-9400 FnAic No: (770)813-8535
3473 Satellite Blvd, Suite 114 E-MAIL Y ADDRESS: th der albertservices.com
Duluth, GA 30096 INSURERS AFFORDING COVERAGE NAIC #
INSURERA: Auto Owners Insurance 110190
INSURED umi000n. Arvin nuinnrc Inciwanrn I 1ftaAst
Cribb Philbeck Weaver Group, Inc and CPWG Constructors, LLC INSURERC: Auto UWners Insurance 31/UU
3918 N Highland Ave INSURERD: Allianz Global Cor orate & Specialty SE
Tampa, FL 33603-4724
INSURER E :
INSURER F :
CnVFRAr2FA CERTIFICATE NIIMRFR• nnnnR7n9_1Q777A1 RFVIRION Nt1MRFR- 1R3
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
LTR
TYPE OF INSURANCE
ADDL
ISUBR
POLICY NUMBER
EFF
MM/DDY/YYYY
POLICY
MM/DD EXP
LIMITS
A
X
COMMERCIAL GENERAL LIABILITY
Y
Y
80149474
10/31/2019 10/31/2020
EACH OCCURRENCE
$ 1,000,000
CLAIMS -MADE a OCCUR
DA AGE TO RENTED
PREM SES (Ea occurrence)
$ 300,000
X
MED EXP (Any one person)
$ 10,000
BLAN KET AI
X
BLANKET WOS
PERSONAL&ADV INJURY
$ 1,000,000
GEN'L AGGREGATE LIMIT APPLIES PER:
GENERAL AGGREGATE
$ 2,000,000
!
POLICY 1 PRCT LOC
PRODUCTS - COMP/OP AGG
$ 2,000,000
FL LOCATION
$
OTHER:
AUTOMOBILE LIABILITY
Y
5037622000
06/03/2019 06/03/2020
INEDB
EOa aacid.r SINGLE LIMIT
$ 500 OOO
BODILY INJURY (Per person)
$
ANY AUTO
OWNED SCHEDULED
AUTOS ONLY X AUTOS
HIRED NON -OWNED
AUTOS ONLY AUTOS ONLY
1XX
BODILY INJURY (Per accident)
$
PROPERTY DAMAGE
Per accid ent
tAUTOMA
$
FL Location
$
ADD' X INSURED STATL
IS
A
X
UMBRELLA LIAB
Hx
OCCUR
5037624900
06/03/2019 06/0312020
EACH OCCURRENCE
$ 5,000,000
AGGREGATE
$
EXCESS LIAB
CLAIMS -MADE
DED X I RETENTION $ 10,000
FOLLOWS FORM
$
A
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY
ANY PROPRIETOR/PARTNER/EXECUTIVE YIN
80040655
06/03/2019
06/03/2020
X PER OTH-
STATUTE ER
E.L. EACH ACCIDENT
$ 1,000,000
OFFICERIMEMBER EXCLUDED? ❑
(Mandatory in NH)
N / A
ELL. EA EMPLOYEE
$ 1,000,000
E.L. DISEASE- POLICY LIMIT
$ 1,000,000
If yes, describe under
DESCRIPTION OF OPERATIONS below
C
MO LOCATION
80117967
06/03/2020
06/03/2021
OCC / AGG
$1 MIL / $2 MIL
D
AIRCRAFT HULL & LIAB
UAV1237219
05/30/2019
05/30/2020
COMBINED SINGLE LIM
3,000,000
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)
Collier County Board of County Commissioners is included as an additional insured under the captioned Commercial General
Liability and Automobile Liability Policies on a primary and non-contributory basis if and to the extent required by written
contract.
GENERAL LIABILITY INCLUDES BLANKET ADDITIONAL INSURED (FORM #55373 01107).
GENERAL LIABILITY INCLUDES BLANKET WAIVER OF SUBROGATION (FORM #55091 10/08).
!`COTI CI!'ATC U^1 nCO r`AtVr_FI I ATInN
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
Collier County Board of County Commissioners
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
3295 Tamiami Trail E.
AUTHORIZED REPRESENTATIVE
Naples, FL 34112
THY
C "Ut S-AVII5 ACUKU GUKI ItA I IUN. Au rlgnis reservea.
ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD
Printed by THY on April 09, 2020 at 03:34PM
6�1
A� .�� Q®
CERTIFICATE OF LIABILITY INSURANCE
DATE(MM/DD/YYYY)
04/09/2020
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER
CONTACT Karen Brinkley
NAME:
Iron Ridge Insurance
PHONE (g00) 775-8526 FAX No : (239) 288-7544
(AC,
C No Ext:
E-MAIL kbrinkley@ironridgeinsurance.com
ADDRESS:
4971 Royal Gulf Circle
INSURER(S) AFFORDING COVERAGE
NAIC #
INSURERA: Liberty Insurance Underwriters, Inc
19917
Fort Myers FL 33966
INSURED
INSURER B :
INSURER C :
Cribb Philbeck Weaver Group, Inc.
INSURERD:
3918 North Highland Ave
INSURER E :
INSURER F :
Tampa FL 33603
COVERAGES CERTIFICATE NUMBER: CL196404624 REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAYBE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
LTR
TYPE OF INSURANCE
INSD
WVD
POLICY NUMBER
POLICY EFF
MM/DD/YYYY
POLICY EXP
MM/DD/YYYY
LIMITS
COMMERCIAL GENERAL LIABILITY
EACH OCCURRENCE
$
AMA
CLAIMS -MADE F1 OCCUR
PREMISES Ea occurrence
$
MED EXP (Any one person)
$
PERSONAL&ADV INJURY
$
GEN'L AGGREGATE LIMITAPPLIES PER:
GENERAL AGGREGATE
$
PRO -
POLICY ❑ PRO ❑ JECTLOC
PRODUCTS - COMP/OPAGG
$
$
OTHER:
AUTOMOBILE
LIABILITY
COMBINED SINGLE LIMIT
Ea accident
$
BODILY INJURY (Per person)
$
ANYAUTO
OWNED SCHEDULED
AUTOS ONLY AUTOS
BODILY INJURY (Per accident)
$
PROPERTY DAMAGE
Per accident
$
HIRED NON -OWNED
AUTOS ONLY AUTOS ONLY
$
UMBRELLA LIAB
OCCUR
EACH OCCURRENCE
$
HCLAIMS-MADE
AGGREGATE
$
EXCESS LIAB
DED RETENTION $
$
WORKERS COMPENSATION
PER OTH-
AND EMPLOYERS' LIABILITY Y / N
STATUTE ER
E. L. EACH ACCIDENT
$
ANY PROPRIETOR/PARTNER/EXECUTIVE ❑
OFFICER/MEMBER EXCLUDED?
N/A
ELL EA EMPLOYEE
$
(Mandatory in NH)
If yes, describe under
DESCRIPTION OF OPERATIONS below
E.L. DISEASE- POLICY LIMIT
$
Per Claim
$2,000,000
A
Professional Liability
AEXNYABFENW003
06/03/2019
06/03/2020
Aggregate
$4,000,000
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)
Contract #18-7432-LA Professional Services Library Landscape Architecture
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
Collier County Board of County Commissioners ACCORDANCE WITH THE POLICY PROVISIONS.
3295 Tamiami Trail E
AUTHORIZED REPRESENTATIVE
Naples FL 34112 -f
@ 1988-2015 ACORD CORPORATION. All rights reserved.
ACORD 25 (2016103) The ACORD name and logo are registered marks of ACORD