Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Backup Documents 09/24/2019 Item #16D11 (Chris-Tel Company of SW FL, Inc.)
ORIGINAL DOCUMENTS CHECKLIST & ROUTING SLI • 1 1 TO ACCOMPANY ALL ORIGINAL DOCUMENTS SENA ' I V E THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR " Print on pink paper. Attach to original document. The completed routing slip and original documents are to be forwarded tl ognty 4,t ey Office at the time the item is placed on the agenda. All completed routing slips and original documents must be received int nby, t Office no later than Monday preceding the Board meeting. **NEW** ROUTING SLIP R� Ir Complete routing lines#1 through#2 as appropriate for additional signatures,dates,and/or information needed. If the document is 21Y PAm [e e wei{Iht the exception of the Chairman's signature,draw a line through routing lines#1 through#2,complete the checklist,and forward to the County Attorney Office. Route to Addressee(s) (List in routing order) Office Initials Date 1. Risk Risk Management 64„. elbt,I15 2. County Attorney Office County Attorney Office 5./ vv-7/1 7. 4. BCC Office Board of County WY`n b Commissioners Jry51 4. Minutes and Records Clerk of Court's Office 2( i(@ 3. y1V �" e& 5. Procurement Services Procurement Services PRIMARY CONTACT INFORMATION Normally the primary contact is the person who created/prepared the Executive Summary. Primary contact information is needed in the event one of the addressees above,may need to contact staff for additional or missing information. Name of Primary Staff Ana Reynoso/PURCHASING Contact Information 239-252-8950 Contact/ Department Agenda Date Item was September 24,2019 Agenda Item Number 16.D.11. Approved by the BCC Type of Document CONTRACT Number of Original 2 Attached Documents Attached PO number or account N/A 19-7646 Chris-Tel Comp number if document is Chris-Tel Company of Southwest to be recorded of Southwest Florida, Inc. Florida, Inc. INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable column 'chever is Yes N/A(Not appropriate. (Initial) Applicable) 1. Does the document require the chairman's original signature STAMP 0 N/A 2. Does the document need to be sent to another agency for adi:itional si atures? If yes, N/A provide the Contact Information(Name;Agency;Address; one an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be AR signed by the Chairman,with the exception of most letters,must be reviewed and signed by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the AR document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's AR signature and initials are required. 7. In most cases(some contracts are an exception),the original document and this routing slip N/A should be provided to the County Attorney Office at the time the item is input into SIRE. Some documents are time sensitive and require forwarding to Tallahassee within a certain time frame or the BCC's actions are nullified. Be aware of your deadlines! 8. The document was approved by the BCC on 09/24/2019 and all changes made during N/A is not the meeting have been incorporated in the attached document. The County JS. an option for Attorney's Office has reviewed the changes,if applicable. this line. 9. Initials of attorney verifying that the attached document is the version approved by the N/A is not BCC,all changes directed by the BCC have been made,and the document is ready for the ` an option for Chairman's signature. r" this line. 16 0 11 MEMORANDUM Date: October 1, 2019 To: Ana Reynoso, Procurement Services From: Martha Vergara, Sr. Deputy Clerk Minutes & Records Department Re: Contract #19-7646 "General Contractors for Public Transit Construction Projects" Multi-Contractor Award Agreement Contractor: Chris-Tel Company of SW Florida, Inc. Attached for your records is an original of the referenced document above, (Item #16D11) adopted by the Board of County Commissioners on Tuesday, September 24, 2019. The Board's Minutes & Records Department has kept an original as part of the Board's Official Records. If you have any questions, please feel free to contact me at 252-7240. Thank you. Attachment 16011 MULTI-CONTRACTOR AWARD AGREEMENT # 19-7646 for General Contractors for Public Transit Construction Projects THIS AGREEMENT, made and entered into on this ` day of "U 20 , by and between Chris-Tel Company of Southwest FL, Inc. dba Chris-Tel Construction , authorized to do business in the State of Florida, whose business address is 2534-A Edison Avenue, Fort Myers, Florida 33901 , (the "Contractor") and Collier County, a political subdivision of the State of Florida, (the "County" or "Owner"): WITNESSETH: 1. AGREEMENT TERM. The Agreement shall be for a five (5 ) year period, commencing ■I upon the date of Board approval , and terminating five (5 ) year(s) from that date or until all outstanding Iii Purchase Order(s) n k-Qfdee($ issued prior to the expiration of the Agreement period have been completed or terminated. The County may, at its discretion and with the consent of the Contractor, renew the Agreement under all of the terms and conditions contained in this Agreement for one (1) additional five ( 5 ) year(s) periods. The County shall give the Contractor written notice of the County's intention to renew the Agreement term prior to the end of the Agreement term then in effect. The County Manager, or his designee, may, at his discretion, extend the Agreement under all of the terms and conditions contained in this Agreement for up to one hundred and eighty (180) days. The County Manager, or his designee, shall give the Contractor written notice of the County's intention to extend the Agreement term prior to the end of the Agreement term then in effect. 2. COMMENCEMENT OF SERVICES. The Contractor shall commence the work upon issuance of a (■,Purchase Order ■ Notice to Proceed. 3. STATEMENT OF WORK. The Contractor shall provide services in accordance with the terms and conditions of n Request for Proposal (RFP) n . - - - _ ■ Other Request for Qualification (RFQ ) # 19-7646 , including all Attachment(s), Exhibit(s) and Addenda and the Contractor's proposal referred to herein and made an integral part of this Agreement. ■ The Contractor shall also provide services in accordance with Exhibit A — Scope of Services attached hereto. 3.1 This Agreement contains the entire understanding between the parties and any modifications to this Agreement shall be mutually agreed upon in writing by the Parties, in compliance with the County's Procurement Ordinance, as amended, and Procurement Procedures in effect at the time such services are authorized. Page 1 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1:7i) 16 D11 3.2 The execution of this Agreement shall not be a commitment to the Contractor to order any minimum or maximum amount. The County shall order items/services as required but makes no guarantee as to the quantity, number, type or distribution of items/services that will be ordered or required by this Agreement. 3.3 ■ The procedure for obtaining Work under this Agreement is outlined in Exhibit A — Scope of Services attached hereto. ❑ . . _. - --- . . --..-. - •- ❑ Other Exhibit/Attachment: - ___ - -w, - -- _ _ .-. - . _ "-. _- _ e _ _ . . ..• . •e e A 1- .:cecc . - • A 4. THE AGREEMENT SUM. n The County shall pay the Contractor for the performance of this Agreement based on Work performed pursuant to the quoted price offered by the Contractor in response to a specific Request for Quotations and pursuant to the Price Methodology in Section 4.1. Contractor's quoted _ _ •. _ e- -e e* e _ e e - . • . e . e. Payment will be made upon receipt of a proper invoice and upon approval by the County's Contract Administrative Agent/Project Manager, and in compliance with Chapter 218, Fla. Stats., otherwise known as the "Local Government Prompt Payment Act". maximum amount of _. .. ($ ), -.• _ . - - __ - _ . e ._ . . _ '_- 1,1_- --- - • _ .-. . 1 I Contractor's quoted prices shall be based on Exhibit B Fee Schedule. Contract Administrative Agent/Project Ma -=- , - -e -e•-= • •-- - •- e - - -., otherwise known as the "Local Government Prompt Payment Act". 4.1 Price Methodology (as selected below): TO Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the County to the contractor; and, as a business practice there are no hourly or material invoices presented, rather, the contractor must perform to the satisfaction of the County's project manager before payment for the fixed price contract is authorized. n Time and Materials: The County agrees to pay the contractor for the amount of labor time spent by the contractor's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's markup). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. Page 2 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16011 n - •' - '. .- _ e -- e e-, _ it-rra-total fixed price (inclusive of all costs, including labor, materials, equipment, overhead, etc.) for a repetitive product or service delivered (i.e. unit price and the number of units received (no contractor inventory or cost verification). 4.2 Any County agency may obtain services under this Agreement, provided sufficient funds are included in their budget(s). 4.3 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of the Agreement. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. 474 n . . - . .. . e . e . . -- ..e- -- = - e- _ *- Section 112.061 Fla. Stats. Reimbursements shall be at the following rates: Mil ago $0.44.5 per mile Breakfast $6.00 Lunch $4-1-98 Sinner $49-00 Airfare - Rental-ear - L-edging - _-. .- .. _ . - • - .. _ _ Parking A • -- -• • -- Reimbursable items other than travel expenses shall be limited to the following: telephone long paid only after Contractor has provided all receipts. Contractor shall be responsible for all otheF costs and expenses associated with activities and solicitations undertaken pursuant to this Agreement. 5. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. Collier County, Florida as a political subdivision of the State of Florida, is exempt from the payment of Florida sales tax to its vendors under Chapter 212, Florida Statutes, Certificate of Exemption # 85-8015966531C. Page 3 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 161311 6. NOTICES. All notices from the County to the Contractor shall be deemed duly served if mailed or emailed to the Contractor at the following: Chris-Tel Company of Southwest Florida, Inc. Company Name: dba Chris-Tel Construction Address: 2534-A Edison Avenue Fort Myers, Florida 33901 Authorized Agent: Howard L. Wheeler, II, President Attention Name & Title: Telephone: (239) 226-0500 E-Mail(s): Hwheeler@christelconstruction.com All Notices from the Contractor to the County shall be deemed duly served if mailed or emailed to the County to: Board of County Commissioners for Collier County, Florida Division Director: Michelle Edwards Arnold Division Name: Public Transit & Neighborhood Enhancement Address: 3299 East Tamiami Trail, #103 Naples, Florida 34112 Administrative Agent/PM: Liz Soriano, Project Manager Telephone: (239) 252-6081 E-Mail(s): Liz.Soriano@colliercountyfl.gov The Contractor and the County may change the above mailing address at any time upon giving the other party written notification. All notices under this Agreement must be in writing. 7. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a partnership between the County and the Contractor or to constitute the Contractor as an agent of the County. 8. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, F.S., all permits necessary for the prosecution of the Work shall be obtained by the Contractor. The County will not be obligated to pay for any permits obtained by Subcontractors. Payment for all such permits issued by the County shall be processed internally by the County. All non-County permits necessary for the prosecution of the Work shall be procured and paid for by the Contractor. The Contractor shall also be solely responsible for payment of any and all taxes levied on the Contractor. In addition, the Contractor shall comply with all rules, regulations and laws of Collier County, the State of Florida, or the U. S. Government now in force or hereafter adopted. The Contractor agrees to comply with all laws governing the responsibility of an employer with respect to persons employed by the Contractor. 9. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any manner whatsoever, County facilities for any improper, immoral or offensive purpose, or for any purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation, Page 4 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1 D11 or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the event of such violation by the Contractor or if the County or its authorized representative shall deem any conduct on the part of the Contractor to be objectionable or improper, the County shall have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24) hours after receiving notice of such violation, conduct, or practice, such suspension to continue until the violation is cured. The Contractor further agrees not to commence operation during the suspension period until the violation has been corrected to the satisfaction of the County. 10. TERMINATION. Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County as per this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be the sole judge of non-performance. In the event that the County terminates this Agreement, Contractor's recovery against the County shall be limited to that portion of the Agreement Amount earned through the date of termination. The Contractor shall not be entitled to any other or further recovery against the County, including, but not limited to, any damages or any anticipated profit on portions of the services not performed. 11. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race, sex, color, creed or national origin. 12. INSURANCE. The Contractor shall provide insurance as follows: A. El Commercial General Liability: Coverage shall have minimum limits of$ 1,000,000 Per Occurrence, $2,000,000 aggregate for Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. B. El Business Auto Liability: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership. C. • Workers' Compensation: Insurance covering all employees meeting Statutory Limits in compliance with the applicable state and federal laws. The coverage must include Employers' Liability with a minimum limit of$ 1,000,000 for each accident. D. ❑ • : - • - - •• - • - • - - • - - - • . . - - - •-• leepgal iabili f o c-1 - - •- • - - - - • • - - - -• - - - - - • - -• • --- - • - • • - 'greeme }, Rt a�Y shall each claim and aggregate E ❑ Cyber Liability: Coverage shall have minimum limits of$ per claim. F. n : Cover,age-shall-have-mi imits of$ —pe��laim Special Requirements: Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Page 5 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1613 11 Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Current, valid insurance policies meeting the requirement herein identified shall be maintained by Contractor during the duration of this Agreement. The Contractor shall provide County with certificates of insurance meeting the required insurance provisions. Renewal certificates shall be sent to the County thirty (30) days prior to any expiration date. Coverage afforded under the policies will not be canceled or allowed to expire until the greater of: thirty (30) days prior written notice, or in accordance with policy provisions. Contractor shall also notify County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non- renewal or material change in coverage or limits received by Contractor from its insurer, and nothing contained herein shall relieve Contractor of this requirement to provide notice. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 13. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, whether resulting from any claimed breach of this Agreement by Contractor, any statutory or regulatory violations, or from personal injury, property damage, direct or consequential damages, or economic loss, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 13.1 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, County and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the County or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 14. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the County by the Public Transit & Neighborhood Enhancement Division 15. CONFLICT OF INTEREST. Contractor represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. Contractor further represents that no persons having any such interest shall be employed to perform those services. Page 6 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16 D 11 16. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the following component parts, all of which are as fully a part of the Agreement as if herein set out verbatim: Contractor's Proposal, Insurance Certificate(s), ■ Exhibit A Scope of Services, Exhibit B Fcc Schedule, RFP/I I ITB/■ Other Request for Qualification # 19-7646 , including Exhibits, Attachments and Addenda/Addendum, I I subsequent quotes and corresponding contract documents, n Exhibit C-1 Public Payment Bond, ■ Exhibit C-2 Public Performance Bond, [U Exhibit D - Release and Affidavit Form, ■ Exhibit E — Form of Contract Application for Payment, I•l Exhibit F - Change Order, • Exhibit G - Certificate of Substantial Completion, • Exhibit H - Certificate of Final Completion, ❑■ Exhibit I - Warranty, and I■j Other Exhibit/Attachment: Grant Provisions, Certifications and Assurances 17. APPLICABILITY. Sections corresponding to any checked box (R) expressly apply to the terms of this Agreement. 18. SUBJECT TO APPROPRIATION. It is further understood and agreed by and between the parties herein that this Agreement is subject to appropriation by the Board of County Commissioners. 19. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and/or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any Agreement held by the individual and/or firm for cause. 20. COMPLIANCE WITH LAWS. By executing and entering into this Agreement, the Contractor is formally acknowledging without exception or stipulation that it agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to this Agreement, including but not limited to those dealing with the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended; taxation, workers' compensation, equal employment and safety including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 Page 7 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 CM) 161311 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 21. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages and agrees to the successful Contractor extending the pricing, terms and conditions of this solicitation or resultant Agreement to other governmental entities at the discretion of the successful Contractor. 22. U BONDS. A. When a construction project is in excess of $200,000, the Contractor(s) shall be required to provide Payment and Performance Bonds. B. When required by Owner, the Contractor shall furnish a Performance and/or Payment Bond prior to commencing performance, for the full amount of the Work, which shall act as a security guaranteeing the performance of the Contractor's work and the payment by the Contractor to any other party(ies) providing labor and/or materials in connection with each construction or renovation project performed by the Contractor. The bonds shall be furnished using the forms prescribed in Exhibit "C-1" and Exhibit "C-2". C. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business in the State of Florida, terminates or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute another bond and surety, both of which shall be subject to the Owner's approval. Page 8 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1601 1 23. ❑ LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to Proceed to be issued by the Owner. Contractor shall commence the work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. The Work shall be substantially completed within the time specified in the Request for Quotation/Scope of Work. The date of substantial completion of the Work (or designated portions thereof) is the date certified by the Owner when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work(or designated portions thereof) for the use for which it is intended. The Work shall reach final completion and be ready for final acceptance by Owner within the time specified in the Request for Quotation/Scope of Work. Owner and Contractor recognize that since time is of the essence for any work under this Agreement, Owner will suffer financial loss if the Work is not substantially completed within the time specified in the Request for Quotation. Should Contractor fail to substantially complete the Work within the specified time period, Owner shall be entitled to assess as liquidated damages, but not as a penalty, the amount specified in the Request for Quotation/Scope of Work for each calendar day thereafter until substantial completion is achieved. The Project shall be deemed to be substantially completed on the date the Owner issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to substantially complete the Work in a timely manner. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. 24. 0■ PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in excess of thirty (30) days, the Contractor may request to receive Progress Payments. Subsequent to the first payment, Contractor must provide Owner with a fully executed Release and Affidavit in the form attached hereto as Exhibit"D" as a condition precedent to release of each progress payment. All applications for payment, whether for full payment or a progress payment shall be in writing, and in substantially the form attached hereto as Exhibit "E." 25. PAYMENTS WITHHELD. Owner may decline to approve any application for payment, or portions thereof, because of defective or incomplete work, outstanding punchlist items, subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other Agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence indicating probable fling of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the Page 9 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16011 unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents. If any conditions described above are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other Agreement between Contractor and Owner. 26. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from specifications shall be approved in writing by Owner in advance. 27. IMI CONTRACT TIME AND TIME EXTENSIONS. A. Time is of the essence in the performance of any Work under this Agreement and Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and materialmen, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's supplies and contractors. B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. C. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 28. • CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any modifications to this Agreement shall be in compliance with the County's Page 10 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 S 16011 Procurement Ordinance and Procurement Procedures in effect at the time such modifications are authorized. A Change Order in the form attached as Exhibit "F" to this Agreement, shall be issued and executed promptly after an Agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 29. ■ CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean. 30. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on County projects who are neat, clean, well-groomed and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The County may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Collier County projects is not in the best interest of the County. 31. 0 TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish to the County the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the County. 32. ■ PROTECTION OF WORK. A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or anyone for whom Contractor is legally liable is responsible for any loss or damage to the Work, or other work or materials of the County or County's separate contractors, Contractor shall be charged with the same, and any monies necessary to replace such loss or damage shall be deducted from any amounts due Contractor. B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. C. Contractor shall not disturb any benchmark established by the County with respect to the Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally liable, disturbs the County's benchmarks, Contractor shall immediately notify the County. The County shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by the County associated therewith. 33. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner is obligated to act to prevent threatened damage, injury or loss. Page 11 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 CAO 16011 Contractor shall give the Owner written notice within forty-eight (48) hours after the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Owner determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 34. ■ COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such designated portion) is substantially complete and request that Owner issue a Certificate of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner does not consider the Work (or designated portion) substantially complete, the Owner shall notify Contractor in writing giving the reasons therefor. If Owner considers the Work (or designated portion) substantially complete, Owner shall prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit G, which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punchlist of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punchlist. Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Owner will make such inspection and, if Owner finds the Work acceptable and fully performed under the Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit H, recommending that on the basis of Owner's observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Final payment shall not become due and payable until Contractor submits: A. The Release and Affidavit in the form attached as Exhibit "D." B. Consent of Surety (if applicable) to final payment. C. If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. D. The warranty in the form attached as Exhibit "I". Owner reserves the right to inspect the Work and make an independent determination as to the acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment shall not become due and payable. Page 12 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16011 35. n WARRANTY. Contractor expressly warrants that the goods, materials and/or equipment covered by this Agreement will conform to the requirements as specified, and will be of satisfactory material and quality production, free from defects, and sufficient for the purpose intended. Goods shall be delivered free from any security interest or other lien, encumbrance or claim of any third party. Any services provided under this Agreement shall be provided in accordance with generally accepted professional standards for the particular service. These warranties shall survive inspection, acceptance, passage of title and payment by the County. Contractor further warrants to the County that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after final completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from the County. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. These warranties are in addition to those implied warranties to which the County is entitled as a matter of law. 36. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect. 37. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this Agreement in compliance with the Procurement Ordinance, as amended, and Procurement Procedures. 38. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision-making authority and by County's staff person who would make the presentation of any settlement reached during negotiations to County for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision-making authority and by County's staff person who would make the presentation of any settlement reached at mediation to County's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 39. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 40. - 0 - - e • - - - ' e•.- - - ••- •-e-••-• e e- _ . . -- - " - - -- investigations as may be deemed necessary to ensure that competent persons will be utilized in Page 13 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 161311 complete the services on a timely basis, and ach person assigned shall be available for an Personnel unless the following conditions arc met: (1) Proposed replacements have substantially the same or bcttcr qualifications and/or experience. (2)-that the County is notified in writing as far n AGREEMENT STAFFING. The Contractor's personnel and management to be utilized for this Agreement shall be knowledgeable in their areas of expertise. The County reserves the right to perform investigations as may be deemed necessary to ensure that competent persons will be utilized in the performance of the Agreement. The Contractor shall assign as many people as necessary to complete required services on a timely basis, and each person assigned shall be available for an amount of time adequate to meet required services. 41. ❑ o - , - . - - _ ! , - •- - e • e• • --e-_ •- - _ . e- !e ••-- - .. • e . . -. Board approved Executive Summary, the Contract Documents shall take precedence. n ORDER OF PRECEDENCE (Grant Funded). In the event of any conflict between or among the terms of any of the Contract Documents and/or the County's Board approved Executive Summary, the terms of the Agreement shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Agreement. To the extent any conflict in the terms of the Contract Documents cannot be resolved by application of the Supplemental Conditions, if any, or the Agreement, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at County's discretion. 42. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of the County. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the County's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward the County. 43. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five (5) years and the Contractor shall be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their Page 14 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 0 16011 background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e- mail (DL-FMOPS@colliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of$500 per incident. 44. SAFETY. All Contractors and subcontractors performing service for Collier County are required and shall comply with all Occupational Safety and Health Administration (OSHA), State and County Safety and Occupational Health Standards and any other applicable rules and regulations. Also, all Contractors and subcontractors shall be responsible for the safety of their employees and any unsafe acts or conditions that may cause injury or damage to any persons or property within and around the work site. Collier County Government has authorized the Occupational Safety and Health Administration (OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of inspection of any Contractor's work operations. This provision is non-negotiable by any division/department and/or Contractor. All applicable OSHA inspection criteria apply as well as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow OSHA onto a project that is being performed on Collier County Property. Collier County, as the owner of the property where the project is taking place shall be the only entity allowed to refuse access to the project. However, this decision shall only be made by Collier County's Risk Management Division Safety Manager and/or Safety Engineer. (Intentionally left blank-signature page to follow) Page 15 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 t 1 16011 IN WITNESS WHEREOF, the parties hereto, by an authorized person or agent, have executed this Agreement on the date and year first written above. ATTEST: BOARD OF C'. OMMISSIONERS COLLIE Ce e Y, FLO- •A Crystal K. Kinzel, Cleric of=Courts & - I • OA Co p .i By: Mat : ,,r :,, , . -4 , By: —• or- Wliam L. McDaniel Jr. , Chairman Dated: - 4 . -' .' 96 (SEAL) ' es as o cirlirmans 5 igtlature'only, Chris-Tel Company of Southwest Florida, Inc. Contractor's Witnesses: dba Chris-Tel Construction 1 Contractor By: CoMractor's First Witness - gnature Howard L. Wheeler, II, President Julie De Piro TType/print signature and titleT TType/print witness namet Co 't, or a co d Witness Molly Scott trype/print witness namels prover tem d L(gality: ...c„,„, iti bekil County Attorney r-- Print Name Page 16 of 33 Multi-Contractor Award Agreement 2017.006 4g/1 CAO tout ' Exhibit A Scope of Services (U following this page (pages 1 through 6 ) P1 this exhibit is not applicable Page 17 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16811 #19-7646 "General Contractors for Public Transit Construction Projects" EXHIBIT A SCOPE OF SERVICES 1. Scope of Work 1.1. The General Contractor will be responsible for providing complete construction services for a wide range of projects and also responsible for the overall coordination of a project. The General Contractor will provide material, labor, equipment, tools and services necessary for all projects assigned. When necessary, the General Contractor may hire specialized subcontractors to perform all, or some portion of the construction work. 1.2.The General Contractor must be qualified and is directly responsible for 100% of the contracted work including all work performed by the in-house personnel or any subcontractors. In the event the General Contractor does not "self-perform" any or all tasks within the specifications, and utilizes subcontractors, the General Contractor is directly responsible for all supervision, monitoring and compliance with one hundred percent (100%) of meeting schedule, cost, work scope plans and specification quality in the performance of a project for the County. 1.3.The selected General Contractors may be involved in: 1.3.1.Construction supervision/administration; 1.3.2.New construction; 1.3.3.Renovations/retrofits/remediation; 1.3.4.Site or utility improvements; 1.3.5.Complete or selective demolition; 1.3.6.Estimating cost of future projects; 1.3.7.Coordinating with project consultants; and, 1.3.8.Scheduling work and subcontractors in harmony with the County's operations; 1.3.9.Coordination of design and engineering services per F.S.287.017 Category 5 good faith estimate of construction cost of$325,000.00. 1.4. The selected General Contractors' responsibilities may include, but are not limited to: 1.4.1. Hiring various trades to complete a project; 1.4.2. Applying for building permits; 1.4.3. Securing the property; 1.4.4. Providing temporary utilities on site; 1.4.5. Managing personnel on site; and 1.4.6. Disposing and/or recycling of construction waste, monitoring schedules and cash flows, and maintaining accurate records; 1.4.7. Subcontracting design and/or engineering services relative to the work required per F.S.287.017 Category 5 good faith estimate of construction cost of$325,000.00. The above list is not intended to represent the entire GC portfolio, but rather, a sample of the various responsibilities that a GC may be requested to participate in for a Collier County project. 2. Procedures for Obtaining Work Assignments 2.1. For all projects, the County's Project Manager will follow the procedure outlined below to receive Page 1 of 6 CAO 1 601 1: quotes from the selected General Contractors. 2.1.1. A Summary of Work, Project Plans, Technical Specifications, etc. will be provided to all of the selected contractors, along with a quote schedule for providing price. The County's Project Manager may assess Liquidated Damages per work assignment. 2.1.2. The County Project Manager will set the required response time for each project, but Contractors will be given a minimum of ten (10) business days to provide a quote. Other projects may require longer quoting period to allow for proper coordination. Some projects, urgent in nature, may require a shorter response schedule at the Project Manager's discretion. This period may also include a pre-bid meeting. 2.1.3. Contractors shall provide a lump sum quote,based on the quote schedule provided.The following is an example of a quote schedule that may be required: Item Description Unit Amount Item Cost Number 1 Mobilization Lump Sum 1 $0.00 2 Sitework Lump Sum 1 $0.00 3 Masonry Lump Sum 1 $0.00 4 Structural Lump Sum 1 $0.00 5 Roofing Lump Sum 1 $0.00 6 Plumbing Lump Sum 1 $0.00 7 HVAC Lump Sum 1 $0.00 8 Electrical Lump Sum 1 $0.00 $0.00 9 Owner's Allowance T&M $0.00 Lump Sum Total $0.00 2.1.4. Ancillary charges may be transferred to the County in the actual amount; however, mark-ups will not be allowed. Mark-ups will not be allowed on sales tax, consumer fees or taxes, use and other similar taxes, or fees associated with any work under this Agreement. 2.1.5. The Project Manager will review all of the quotes and may negotiate with the Contractor who submits the lowest quote, if outside of the budget. 2.1.6. All work assignments that exceed $200,000 for any one project, will require Board approval. 2.1.7. Performance and Payment Bonds will be required for projects over $200,000. 2.1.8. Once a contractor is selected for a work assignment, the County's Project Manager will issue a Purchase Order. 2.1.9. The contractor may not begin work until a written Notice to Proceed is issued from the County's Project Manager or designee. 3. General Requirements 3.1. Performance and Payment Bonds: Page 2 of 6 :'aa 16011 When a work assignment is in excess of$200,000.00, the Contractor(s) shall be required to provide Performance and Payment Bonds, in the amount of 100%of the quoted work assignment amount;the costs of which is to be paid by Contractor. If the work assignment will be more than thirty (30) days in duration and less than $200,000.00, the County's project manager may request Payment and Performance Bonds. All performance security under the subsequent work assignment shall be continued for a six (6) month period beyond the final completion of the project. 3.2. Progress Payments: For work that will not be completed within a thirty (30) day period, the Contractor may wish to receive Progress Payments. Subsequent to the first Application for Payment, the Contractor shall submit to the County, for their review and approval,a schedule of values based upon the total amount to be paid to the Contractor. The Schedule of Values will be formatted by the Contractor to provide for necessary cost breakdowns of the Work by trade category. After its approval by the Owner, that schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. The first Application for Payment shall be submitted no earlier than thirty(30)days after the issuance of the purchase order and Notice to Proceed. 3.3. Insurance/Disaster Related Repairs: For insurance related repairs/work, the Contractor may be asked to provide an itemized breakdown of materials, labor and associated costs necessary for submittal to Risk Management. For disaster related repairs/work, the Contractor may be asked to provide an itemized breakdown of materials, labor and associated costs necessary for submittal to Risk Management. If FEMA related, the Contract will be required to comply with the term and condition in the attached provisions (i.e. Lump Sum Only) and will be defined within the work assignment issued by the County as applicable. 3.4. Equipment Inventory: The Contractor(s) shall, under no circumstances, remove any equipment containing a County asset sticker,without written authorization from the County staff.The Contractor(s)shall request that,when replacing equipment, the asset sticker be removed by an appropriate County staff member authorized to adjust equipment inventory records. 3.5. Facility Safety, Security and Standards: The contractor and their subcontractors are required to comply with County Ordinance 2004-52, as amended and all future changes. Background checks are valid for five (5) years and the vendor / subcontractor shall be responsible for all associated costs.The cost is$40.00 per person.At all times, the contractor and their subcontractors must wear the assigned Contractor badge while conducting work on County property. Work assignments must be performed in accordance with standards and guidelines set by the County's Project Manager. The Contractor(s) will comply with all applicable federal, state and local laws,ordinances, rules and regulations pertaining to the performance of the services requested herein. Any fines levied due to inadequacies, or failure to comply with any requirements, will be the sole responsibility of the Contractor(s). Any employee or representative of the Contractor(s) found not in conformance with any laws, statutes, rules or regulations will not be allowed on job sites. Violations by a Contractor may constitute cause for immediate termination of the Agreement. The Contractor(s) Page 3 of 6 16011 shall replace or repair any loss at their cost. The County may withhold payment or make such deductions as it may deem necessary to insure reimbursement for loss or damage to property or persons through negligence of the Contractor and its employees. Contractor is expected to understand and comply with all applicable laws and regulations of any applicable governmental entity and Collier County CMA's, Standard Operating Procedures (SOP's) or Job Safety Analysis (JSA's) that that pertain to environmental, health and safety standards and/or work practices applicable to the activities they perform. Contractor must agree that all work must meet or exceed the standards set forth in the Collier County Vertical Construction Standards and Collier County IT Construction Standards (if applicable) unless specifically exempted in writing by Facilities Management Division Representative or designee. The Contractor(s) must comply with Federal and State right-to-know laws if hazardous materials are used. Material Safety Data Sheets(MSDS)will be made available and provided to the County per the County Representative's direction. The Contractor is required to immediately report to the County Representative or designee any spillage or dumping of hazardous material on County property. The Contractor shall bear all costs associated with the cleanup of any such incidents. 3.6. High Security Environments: The successful Contractor(s) will be asked to work in the Collier County Sheriff Office Correctional Facilities and other areas considered "high security", which require thorough background checks of personnel and tools taken into such Facilities. Additional access and logistical requirements for high security sites may be set at the Project Manager's discretion in the Summary of Work during work assignments. 3.7. Warranty: All new equipment/parts warranty work shall be provided by the original warranty supplier. All warranty responsibility for parts or equipment previously purchased, but still under warranty will continue to be provided by the original warranty supplier until expiration of the warranty period. 3.8. Trouble Calls: All trouble calls are initially reported to Facilities Management.If the trouble call involves a warranty item, the County Project Manager shall notify the Contractor, who will then have the responsibility of placing the warranty trouble call with the warranty supplier and tracking the problem until it has been fully remedied.Maintenance of a warranty inventory list for each completed project through the warranty period and the tracking of warranty trouble calls shall be provided by the Contractor at no additional cost to the County. 3.9. Parts and Fixtures: Parts and fixtures shall be new and warranted for a minimum of one (1) year or the standard offered by the manufacturer, whichever is greater, after acceptance of the Project. All labor for repairs shall have a minimum of ninety (90) day warranty. All call backs will be free of charge. No labor will be billed or allowable in the event defective parts were used. An extended warranty and/or service agreement may be purchased through the Contractor from the manufacturer without any markup being charged to the County. Page 4 of 6 1613 11 3.10. Express Warranties: Contractor shall obtain and assign to the County all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to the County that any materials and equipment furnished under the Contract shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract. Contractor further warrants to the County that all materials and equipment furnished under the Contract shall be applied, installed, connected,erected,used,cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract, Contractor shall correct it promptly after receipt of written notice from the County.Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency,the County may commence to correct any defective Work,without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which the County is entitled as a matter of law. 3.11. Changes in the Work Contractor shall provide Owner with a Time and Material Not to Exceed (T&M NTE) proposal for any changes in the work. The proposal shall include breakdown of Contractor's time, materials and any proposed subcontractor quotes. Invoicing for all T&M NTE work shall include backup documentation of Contractor's time,purchased materials and subcontractor invoices. General Contractor(s) selected for this contract agree to the following, as pertains to markups on Change Order Work: The mark-up on rental equipment shall not exceed 10% and equipment owned by the contractor utilized on a project will not be charged back to the owner. The mark-up on subcontractors shall not exceed 15%. The mark-up on materials shall not exceed 20%. The Labor rates provided by the Contractor as a part of a change order, relative to labor rates pertaining to changes in the work, are to be fully burdened to include overhead, insurance, profit and use of company owned small tools and equipment. Some work assignments will utilize a fee schedule for labor categories and parts unit pricing. Fee schedule rates,which are subject to additions or deletions,will be negotiated with the selected vendors and will be added to the work assignment in the form of a fee schedule for utilization. 3.12. Compliance with County Risk Management Requirements Contractors will be expected to understand and comply with all applicable laws and regulations of any Page 5 of 6 1613 11 governmental entity having jurisdiction and Collier County CMA's, Standard Operating Procedures (SOP's) or Job Safety Analysis (JSA's) that that pertain to environmental, health and safety standards and/or work practices applicable to the activities they perform. These include but are not limited to: • Storage, handling, and use of flammable liquids and hazardous materials. • Storage, handling, and use of compressed gas cylinders. • Periodic safety inspections of equipment and work-site housekeeping. • Use of fall protection while working at heights above 6 feet. • Following electrical safety practices and lock out/tag out procedures. • Proper use of personal protective equipment. • Proper maintenance and use of ladders and other equipment. • Guarding of wall and floor openings, open trenches, and excavations. 4. Applicable Articles The following Articles of the Agreement shall only be applicable for Projects over $200,000; Article 22. Bonds Article 23. Liquidated Damages Article 24. Payments Article 34. Completion Page 6 of 6 161311 Exhibit B Fee Schedule (l following this page (pages through ❑� this exhibit is not applicable Page 18 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1 6 D11 Exhibit C-1 I I this exhibit is not applicable PUBLIC PAYMENT BOND Bond No. Contract No. KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and , as Surety, located at (Business Address) are held and firmly bound to as Oblige in the sum of ($ ) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of , 20_ with Oblige for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect sureties' obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.0592. In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20_, the name of under-signed representative, pursuant to authority of its governing body. Page 19 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 CAO 16Dh1 Signed, sealed and delivered in the presence of: PRINCIPAL: By: Witnesses as to Principal Name: Its: STATE OF COUNTY OF The foregoing instrument was acknowledged before me this of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: ATTEST: SURETY: (Printed Name) (Business Address) (Authorized Signature) Witness as to Surety (Printed Name) OR Page 20 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16011 As Attorney in Fact (Attach Power of Attorney) Witnesses (Business Address) (Printed Name) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me this of 20 , by_ , as of , Surety, on behalf of Surety. He/She is personally known to me OR has produced as identification and who did(did not)take an oath. My Commission Expires: (Signature of Notary) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: Page 21 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1601k ❑ this exhibit is not applicable EXHIBIT C-2 PUBLIC PERFORMANCE BOND Bond No. Contract No. KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and , as Surety, located at (Business Address) are held and firmly bound to , as Oblige in the sum of ($ ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the_day of 20 , with Oblige for in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract, and 2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Oblige; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or to work or to the specifications. Page 22 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 161311 This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this Performance bond regardless of the number of suits that may be filed by Oblige. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20_, the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. Signed, sealed and delivered in the presence of : PRINCIPAL: By: Witnesses as to Principal Name: Its: STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 by , as of , a corporation, on behalf of the corporation. He/She is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: Page 23 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 bull ATTEST: SURETY: (Printed Name) (Business Address) (Authorized Signature) Witness as to Surety (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) Witnesses (Business Address) (Printed Name) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of , 20_, by , as of , Surety, on behalf of Surety. He/She is personally known to me OR has produced as identification and who did(did not) take an oath. My Commission Expires: (Signature of Notary) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: Page 24 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 CAO 16011 ❑ this exhibit is not applicable EXHIBIT D RELEASE AND AFFIDAVIT FORM COUNTY OF ( ) STATE OF (_ Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final]Application for Payment No. CONTRACTOR BY: Witness ITS: DATE: Witness [Corporate Seal] STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of , 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me or has produced as identification and did (did not)take an oath. My Commission Expires: (Signature of Notary) NAME: (Legibly Printed) Notary Public, State of (AFFIX OFFICIAL SEAL) Commissioner No.: Page 25 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 (1'AC) 1 6 D 11 f 1 this exhibit is not applicable EXHIBIT E FORM OF CONTRACT APPLICATION FOR PAYMENT Bid No. (County Project Manager) PO No. (County Department) Collier County Board of County Commissioners(the OWNER) or Project No. Collier County Water-Sewer District(the OWNER) Application Date FROM: (Contractor's Representative) Payment Application No. (Contractor's Name) for Work accomplished through the Date: (Contractor's Address) RE: (Project Name) Original Contract Time: Original Contract Amount: $ Revised Contract Time: Total Change Orders to Date $ Revised Contract Amount $ Total value of Work Completed Retainage @ 1 0% thru[insert date] $ and stored to Date $ Retainage @ __% after [insert date] $ Less previous payment(s) $ Percent Work completed to Date: % AMOUNT DUE THIS Percent Contract Time completed to Date % APPLICATION: $ Liquidated Damages to be Accrued $ ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2)title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the revised contract and shall be incorporated into a future Change Order: By CONTRACTOR: (Contractor's Name) (Signature) DATE: (Type Name&Title) (shall be signed by a duly authorized representative of CONTRACTOR) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLI CATION is recommended: By Design Professional : (DP's Name) (Signature) DATE: (Type Name&Title) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLI CATION is approved: By OWNER'S Project Manager: (Signature) DATE: (Type Name and Title) Page 26 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 "i".f ] 6D11 ❑ this exhibit is not applicable EXHIBIT F CHANGE ORDER ❑ Contract Modification ❑Work Order Modification Contract#: Change#: Purchase Order#: Project#: Contractor/Firm Name: Project Name: Project Manager Name: Department: Original Contract/Work Order Amount Original BCC Approval Date; Agenda Item # Current BCC Approved Amount Last BCC Approval Date; Agenda Item # Current Contract/Work Order Amount SAP Contract Expiration Date (Master) Dollar Amount of this Change #DIV/0! Total Change from Original Amount Revised Contract/Work Order Total $ 0.00 #DIV/0! Change from Current BCC Approved Amount Cumulative Changes $ 0.00 #DIV/0! Change from Current Amount Completion Date, Description of the Task(s)Change,and Rationale for the Change Notice to Proceed Original Last Approved Revised Date Date Completion Date Date Includes this change) #of Days Added Select Tasks ❑Add new task(s) ❑ Delete task(s) ❑ Change task(s) ❑ Other(see below) Provide a response to the following:1.)detailed and specific explanation/rationale of the requested change(s)to the task(s)and /or the additional days added(if requested);2.)why this change was not included in the original contract;and,3.) describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if needed. Prepared by: Date: (Project Manager Name and Division) Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the same terms and conditions as contained in the contract/work order indicated above,as fully as if the same were stated in this acceptance. The adjustment, if any, to the Contract shall constitute a full and final settlement of any and all claims of the Contractor / Vendor/ Consultant/Design Professional arising out of or related to the change set forth herein, including claims for impact and delay costs. Accepted by: Date: (Contractor/Vendor/Consultant/Design Professional and Name of Firm, if project applicable) Approved by: Date: (Design Professional and Name of Firm, if project applicable) Approved by: Date: (Procurement Professional Page 27 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1 6 13 11 this exhibit is not applicable EXHIBIT G CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. ENGINEER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial completion applies to all Work under the Contract documents or to the following specified parts thereof: To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the contract documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all- inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. Page 28 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 16011 The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: RESPONSIBILITIES: OWNER: CONTRACT OR: The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20_ Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on , 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER By: Type Name and Title Page 29 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 CAO IP6DII II this exhibit is not applicable EXHIBIT H CERTIFICATE OF FINAL COMPLETION OWNER'S Project No. ENGINEER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Final completion applies to all Work under the Contract documents. To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be finally complete in accordance with the contract documents on: DATE OF FINAL COMPLETION The warranty in Exhibit I is attached to and made a part of this Certificate: Page 30 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1 6 011 Executed by Design Professional on20_ Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Final Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Final Completion on 20 OWNER By: Type Name and Title Page 31 of 33 Multi-Contractor Award Agreement 2017.006 Ver.1 1 613 1 1 this exhibit is not applicable EXHIBIT I WARRANTY In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the contract either directly performed by the CONTRACTOR or at the express request of the CONTRACTOR by a SUBCONTRACTOR or CONSULTANT. Project Name: Date of Final Completion: Name and Address of CONTRACTOR: CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of all defects of materials and workmanship for a period of one year from the DATE OF FINAL COMPLETION. The undersigned party further agrees that it will, at its own expense, replace and/or repair all defective work and materials and all other work damaged by any defective work upon written demand by the COUNTY. It is further understood that further consideration for this warranty and guaranty is the consideration given for the requirement pursuant to the general conditions and specifications under which the contract was let that such warranty and guaranty would be given. This warranty and guaranty is in addition to any other warranties or guaranties for the work performed under the contract and does not constitute a waiver of any rights provided pursuant to Florida Statutes, Chapter 95, et seq. DATE: CONTRACTOR BY: Attest: Page 32 of 33 Multi-Award Agreement 2017 006 Ver.1 CAO 1 .613 11 Other Exhibit/Attachment Grant Provisions (Exhibit I.A), Certifications and Assurances (Exhibit I.B) Description: (Ui following this page (pages 1 through 48 ) n this exhibit is not applicable Page 33 of 33 Multi-Award Agreement 2017.006 Ver.1 `CAO EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) FEDERAL TRANSIT ADMINISTRATION CFDA 20.507 (URBANIZED AREA FORMULA FUNDING) CFDA 20.526 (BUS AND BUS FACILITIES GRANTS PROGRAM) CFDA 20.527 (PUBLIC TRANSPORTATION EMERGENCY RELIEF PROGRAM) FEMA (U.S. DEPARTMENT OF HOMELAND SECURITY) CONTRACTOR COMPLIANCE OVERVIEW AND REQUIREMENTS The supplemental conditions contained in this section are intended to cooperate with, to supplement, and to modify the general conditions and other specifications. In cases of disagreement with any other section of this contract, the Supplemental Conditions shall govern. Per uniform requirements of federal awards (2 CFR Part 200.23)the definition of CONTRACTOR is an entity that receives a contract. The services performed under 49 U.S.C. 5307 by the awarded Contractor shall be in compliance with all applicable grantor regulations/requirements, and additional requirements specified in this document. It shall be the awarded Contractor's responsibility to acquire and utilize the necessary manuals and guidelines that apply to the work required to complete this project. In general, 1) The contractor (including all subcontractors) must insert these contract provisions in each lower tier contracts (e.g. subcontract or sub-agreement); 2) The contractor (or subcontractor) must incorporate the applicable requirements of these contract provisions by reference for work done under any purchase orders, rental agreements and other agreements for supplies or services; 3) The prime contractor is responsible for compliance with these contract provisions by any subcontractor, lower-tier subcontractor or service provider. STATUTORY AUTHORITY Urbanized Area Formula Program a. Federal Transit Laws, Title 49 U.S.C. 5307 b. 49 CFR 1.51 c. 49 U.S.C. 5339 FTA's Emergency Relief(ER) Program d. 49 U.S.C. 5324 FEMA e. 42 U.S.C. 5121-5206 FTA OVERSIGHT The COUNTY may be subject to a triennial, state management or other regularly scheduled comprehensive review to evaluate performance to determine recipient program and certification compliance. Source,rel,:FTA FY18 Comp.Review Guide Jnr Pracuremeru;DOT PTA FY18 Master Agreement Generally Applicable Prov,v,ens:PTA Herr Practices Prncuremenl Oct 2016 Revised 1-4-19 FCP-1 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) APPLICABLE FTA PROVISIONS APPLICABLE CONTRACT CLAUSE ASSURANCE ® 1. Access to Records and Reports ® 2. Accessibility (Americans with Disabilities Act) ® 3. Additional Employee Protections (Construction Projects) 4. Bonding (Construction Exceeding $250,000) ❑ 5. Bus Testing Certification and Report ® 6. Buy America Certifications>$150K/ Small Purchase Waiver ® 7. Cargo Preference ❑ 8. Charter Service Operations ® 9. Civil Rights Laws and Regulations (EEO,Title VI, &ADA) ® 10. Clean Air Act and Federal Water Pollution Control Act(>$150K) ® 11. Contract Work Hours and Safety Standards Act(>$100,000) ® 12. Copeland Anti-Kickback Act Section 1 and 2 (>$2,000) ® 13. Davis Bacon Act(Applies to Construction >$2,000 DOL Wage Determination ® 14. Debarment and Suspension >$25,000 Certification ® 15. Department of Labor EEO Conditions Complete (2) Forms ® 16. Disadvantaged Business Enterprises (DBEs) (Anticipated DBE Form, Bidders List) ❑ 17. Drug and Alcohol Testing ❑ 18. Employee Protections (Awards Involving Construction) ® 19. Energy Conservation ® 20. Federal Changes ® 21. Federal Privacy Act>$10,000 (and Construction >$2,000) ® 22. Fly America ® 23. Incorporation of Federal Transit Administration (FTA)Terms ❑ 24. ITS Standards (Intelligent Transportation Systems) ® 25. Lobbying (>$100,000) Certification • 26. No Federal Government Obligation to Third Parties by Use of a Disclaimer ❑ 27. Pre-Award and Post Delivery Audits of Rolling Stock Purchases Certifications ❑ 28. Patent Rights, Rights in Data and Copyrights 29. Program Fraud and False or Fraudulent Statements and Related Acts ® 30. Provisions for Resolution of Disputes, Breaches, or Other Litigation (>$150,000) ® 31. Prompt Payment and Return of Retainage(49 C.F.R. part 26 §12. ® 32. Recycled Products (>$10K per Year) ® 33. Safe Operation of Motor Vehicles ❑ 34. School Bus Operations Sources ef PTA FY18('amp.Review Guide for Procurement;DOT PTA FY18 Master Agreement Generally Apphcahle Provisions;FTA Rest Practicet Procurement Oct.2016 Revised 1-4-19 FCP-2 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Z 35. Seismic Safety ® 36. Special DOL EEO Clause for Construction Contracts >$10,000 37. Special Notification Requirements for States (State Grant Provisions) ® 38. Termination Provisions >$10,000 El 39. Transit Employee Protective Arrangements APPLICABLE CONTRACT PROVISIONS (1-39) 1. ACCESS TO RECORDS AND REPORTS (Applies to Subcontracts at Every Tier) a. Record Retention. The Contractor will retain, and will require its subcontractors of all tiers to retain, complete and readily accessible records related in whole or in part to the contract, including, but not limited to, data, documents, reports, statistics, sub-agreements, leases, subcontracts, arrangements, other third- party agreements of any type, and supporting materials related to those records. b. Retention Period.The Contractor agrees to comply with the record retention requirements in accordance with 2 C.F.R. § 200.333. The Contractor shall maintain all books, records, accounts and reports required under this Contract for a period of at not less than three (3) years after the date of termination or expiration of this Contract, except in the event of litigation or settlement of claims arising from the performance of this Contract,in which case records shall be maintained until the disposition of all such litigation,appeals,claims or exceptions related thereto. c. Access to Records. The Contractor agrees to provide sufficient access to FTA and its contractors to inspect and audit records and information related to performance of this contract as reasonably may be required. d. Access to the Sites of Performance. The Contractor agrees to permit FTA and its contractors access to the sites of performance under this contract as reasonably may be required. 2. ACCESSIBILITY(ADA) Facilities to be used in public transportation service must comply with the American with Disabilities Act,42 U.S.C. § 12101 et seq.; DOT regulations, "Transportation Services for Individuals with Disabilities (ADA)," 49 C.F.R. part 37; and Joint Access Board/DOT regulations, "Americans with Disabilities (ADA) Accessibility Specifications for Transportation Vehicles," 36 C.F.R. part 1192 and 49 C.F.R. part 38. Notably, DOT incorporated by reference into Appendix A of its regulations at 49 C.F.R. part 37 the Access Board's "Americans with Disabilities Act Accessibility Guidelines" (ADAAG), revised July 2004, which include accessibility guidelines for buildings and facilities. DOT also added specific provisions to Appendix A of 49 C.F.R. part 37 modifying the ADAAG with the result that buildings and facilities must comply with both the ADAAG and the DOT amendments. 3.ADDITIONAL EMPLOYEE PROTECTIONS ON CONSTRUCTION PROJECTS The Contractor shall comply with U.S. DOL regulations, "Recording and Reporting Occupational Injuries and Illnesses," 29 C.F.R. part 1904; "Occupational Safety and Health Standards," 29 C.F.R. part 1910. 4. BONDING REQUIREMENTS (Applies to Subcontracts at Every Tier) Bid Security A Bid Bond must be issued by a fully qualified surety company acceptable to the COUNTY and listed as a company currently authorized under 31 C.F.R. part 223 as possessing a Certificate of Authority as described thereunder. Rights Reserved In submitting this Bid, it is understood and agreed by bidder that the right is reserved by the COUNTY to reject any and all bids, or part of any bid, and it is agreed that the Bid may not be withdrawn for a period of Sources rel,-FTA 1,Y18 Comp.Review Guide for Procurement DOT V/A FY18 Masser Agreement Generally Applicable Provi.eions,FTA Best Pr acnce.r Proem emenl Oct,2016 Revised 1-4-19 FCP-3 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) [one hundred twenty (120)] days subsequent to the opening of bids, without the written consent of the COUNTY. It is also understood and agreed that if the undersigned bidder should withdraw any part or all of his bid within [one hundred twenty (120)] days after the bid opening without the written consent of the COUNTY, shall refuse or be unable to enter into this Contract, as provided above, or refuse or be unable to furnish adequate and acceptable Performance Bonds and Labor and Material Payments Bonds, as provided above, or refuse or be unable to furnish adequate and acceptable insurance, as provided above, he shall forfeit his bid security to the extent of 'COUNTY's damages occasioned by such withdrawal, or refusal, or inability to enter into an agreement, or provide adequate security therefore. It is further understood and agreed that to the extent the defaulting bidder's Bid Bond, Certified Check, Cashier's Check,Treasurer's Check, and/or Official Bank Check(excluding any income generated thereby which has been retained by the COUNTY as provided in[Item x"Bid Security"of the Instructions to Bidders]) shall prove inadequate to fully recompense the COUNTY for the damages occasioned by default, then the undersigned bidder agrees to indemnify the COUNTY and pay over to the COUNTY the difference between the bid security and (Recipient's) total damages, so as to make the COUNTY whole. The undersigned understands that any material alteration of any of the above or any of the material contained on this form, other than that requested will render the bid unresponsive. Performance and Payment Bonding Requirements (Construction) A contractor or vendor shall provide a surety bond from a surety company to guarantee full and faithful performance of a contract obligation and the payment of labor and material expended pursuant to a contract whenever, and in such amounts, as required by statute or otherwise as deemed necessary by the Purchasing Director. An irrevocable letter of credit from a financial institution operating within the State of Florida(or other alternative forms of surety as permitted under Florida law) may be sufficient in place of the performance bond if so provided for in the bid and contract documents. All such bonds or letters of credit shall be approved as to form by the County Attorney. A. Contractor shall provide Performance and Payment Bonds in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however,the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at https://www.fiscal.treasury.gov/fsreports/ref/suretyBnd/c570.htm. Should the Contract Amount be less than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Advance Payment Bonding Requirements The Contractor may be required to obtain an advance payment bond if the contract contains an advance payment provision and a performance bond is not furnished. The COUNTY shall determine the amount of the advance payment bond necessary to protect the COUNTY. Patent Infringement Bonding Requirements (Patent Indemnity) Soul ces reJ:FTA 1.718 Comp.Review Guide Jo;Proem emery,DOT FTA FY 18 Master Agreement Generally AppItcahle Provisions;FTA Rest Practices Proem orient Ocl.2816 Revised 1-4-19 FCP-4 1 6 011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) The Contractor may be required to obtain a patent indemnity bond if a performance bond is not furnished and the financial responsibility of the Contractor is unknown or doubtful. The COUNTY shall determine the amount of the patent indemnity to protect the COUNTY. Warranty of the Work and Maintenance Bonds 1. The Contractor warrants to the COUNTY,the Architect and/or Engineer that all materials and equipment furnished under this Contract will be of highest quality and new unless otherwise specified by the COUNTY, free from faults and defects and in conformance with the Contract Documents. All work not so conforming to these standards shall be considered defective. If required by the COUNTY Project Manager, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. 2. The Work furnished must be of first quality and the workmanship must be the best obtainable in the various trades. The Work must be of safe, substantial and durable construction in all respects. The Contractor hereby guarantees the Work against defective materials or faulty workmanship for a minimum period of one (1) year after Final Payment by the COUNTY and shall replace or repair any defective materials or equipment or faulty workmanship during the period of the guarantee at no cost to the COUNTY. As additional security for these guarantees, the Contractor shall, prior to the release of Final Payment [as provided in Item X below], furnish separate Maintenance (or Guarantee) Bonds in form acceptable to the COUNTY written by the same corporate surety that provides the Performance Bond and Labor and Material Payment Bond for this Contract. These bonds shall secure the Contractor's obligation to replace or repair defective materials and faulty workmanship for a minimum period of one (1) year after Final Payment and shall be written in an amount equal to ONE HUNDRED PERCENT (100%) of the CONTRACT SUM, as adjusted (if at all). 5. BUS TESTING The Contractor [Manufacturer] agrees to comply with the Bus Testing requirements under 49 U.S.C. 5318(e) and FTA's implementing regulation at 49 C.F.R. part 665 to ensure that the requisite testing is performed for all new bus models or any bus model with a major change in configuration or components, and that the bus model has achieved a passing score. Upon completion of the testing, the contractor shall obtain a copy of the bus testing reports from the operator of the testing facility and make that report(s) publicly available prior to final acceptance of the first vehicle by the recipient. 6. BUY AMERICA REQUIREMENT(Applies to Subtracts.) The contractor agrees to comply with 49 U.S.C. 5323(j)and 49 C.F.R. Part 661,which provide that Federal funds may not be obligated unless steel, iron, and manufactured products used in FTA-funded projects are produced in the United States, unless a waiver has been granted by FTA or the product is subject to a general waiver. General waivers are listed in 49 C.F.R. 661.7, and includes microprocessors, computers, microcomputers, or software, or other such devices,which are used solely for the purpose of processing or storing data. Separate requirements for rolling stock are set out at 49 U.S.C. 5323(j)(2)(C) and 49 C.F.R. 661.11. A bidder or offeror must submit to the FTA recipient the appropriate Buy America certification (Attachments) with all bids or offers on FTA-funded contracts, except those subject to a general waiver. Bids or offers that are not accompanied by a completed Buy America certification must be rejected as nonresponsive. The small purchase waiver is now included in 49 U.S.0 5323(j)(13) and provides that the term "small purchase" means a purchase of not more than $150,000. The small purchase waiver applies to purchases of $150,000 or less, regardless of the size of the project. Therefore, purchases made with FTA financial assistance, including capital, planning, or operating assistance, are subject to the waiver. 7. CARGO PREFERENCE REQUIREMENTS (Applies to Subcontracts) Sources re/,:FTA 8718 Comp.Review Guide for Procurement;DOT FTA FY1N Master-Agreement Generally Applicable Pi ovr.wnns:FTA Rest Practices Procurement Ocl.2016 Revised 1-4-19 FCP-5 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Use of United States-Flag Vessels The contractor agrees: a. to use privately owned United States-Flag commercial vessels to ship at least 50 percent of the gross tonnage (computed separately for dry bulk carriers, dry cargo liners, and tankers) involved, whenever shipping any equipment, material, or commodities pursuant to the underlying contract to the extent such vessels are available at fair and reasonable rates for United States-Flag commercial vessels; b.to furnish within 20 working days following the date of loading for shipments originating within the United States or within 30 working days following the date of leading for shipments originating outside the United States, a legible copy of a rated, "on-board" commercial ocean bill-of-lading in English for each shipment of cargo described in the preceding paragraph to the Division of National Cargo, Office of Market Development, Maritime Administration, Washington, DC 20590 and to the FTA recipient (through the contractor in the case of a subcontractor's bill-of-lading.); and c. to include these requirements in all subcontracts issued pursuant to this contract when the subcontract may involve the transport of equipment, material, or commodities by ocean vessel. 8. CHARTER SERVICE The contractor agrees to comply with 49 U.S.C. 5323(d), 5323(r) and 49 C.F.R Part 604, which provides that recipients and subrecipients of FTA assistance are prohibited from providing charter service using federally funded equipment or facilities if there is at least one private charter operator willing and able to provide the service, except as permitted under: 1. Federal transit laws, specifically 49 U.S.C. § 5323(d); 2. FTA regulations, "Charter Service,"49 C.F.R. part 604; 3.Any other federal Charter Service regulations; or 4. Federal guidance, except as FTA determines otherwise in writing. The contractor agrees that if it engages in a pattern of violations of FTA's Charter Service regulations, FTA may require corrective measures or impose remedies on it. These corrective measures and remedies may include: 1. Barring it or any subcontractor operating public transportation under its Award that has provided prohibited charter service from receiving federal assistance from FTA; 2. Withholding an amount of federal assistance as provided by Appendix D to part 604 of FTA's Charter Service regulations; or 3. Any other appropriate remedy that may apply. The contractor should also include the substance of this clause in each subcontract that may involve operating public transit services. 9. CIVIL RIGHTS LAWS AND REGULATIONS The following requirements apply to the underlying contract and all subcontracts at every tier: CIVIL RIGHTS AND EQUAL OPPORTUNITY The COUNTY is an Equal Opportunity Employer. As such, the COUNTY agrees to comply with all applicable Federal civil rights laws and implementing regulations. Apart from inconsistent requirements imposed by Federal laws or regulations,the COUNTY agrees to comply with the requirements of 49 U.S.C. § 5323(h) (3) by not using any Federal assistance awarded by FTA to support procurements using exclusionary or discriminatory specifications. Under this Agreement, the Contractor shall at all times comply with the following Federal Civil Rights laws and regulations and shall include these requirements in each subcontract entered into as part thereof. Sources rel:FTA 1.Y18 Comp-Review Guide Jot Procurement DOT PTA 1-Y/5 Mailer Agreement Generally ApphcaNle Provicians.PTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-6 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) I. Nondiscrimination. In accordance with Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against any employee or applicant for employment because of race, color, religion, national origin, sex, disability, gender identity or age. In addition, the Contractor agrees to comply with applicable Federal implementing regulations and other implementing requirements FTA may issue. II. Race, Color, Religion, National Origin, Sex. In accordance with Title VII of the Civil Rights Act, as amended, 42 U.S.C. § 2000e et seq., and Federal transit laws at 49 U.S.C. § 5332, the Contractor agrees to comply with all applicable equal employment opportunity requirements of U.S. Department of Labor(U.S. DOL) regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor," 41 C.F.R. chapter 60, and Executive Order No. 11246, "Equal Employment Opportunity in Federal Employment," September 24, 1965, 42 U.S.C. § 2000e note, as amended by any later Executive Order that amends or supersedes it, referenced in 42 U.S.C. §2000e note. The Contractor agrees to take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, national origin, or sex (including sexual orientation and gender identity). Such action shall include, but not be limited to, the following: employment, promotion, demotion or transfer, recruitment or recruitment advertising, layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. III. Age. In accordance with the Age Discrimination in Employment Act, 29 U.S.C. §§ 621-634, U.S. Equal Employment Opportunity Commission (U.S. EEOC) regulations, "Age Discrimination in Employment Act," 29 C.F.R. part 1625, the Age Discrimination Act of 1975, as amended, 42 U.S.C. § 6101 et seq., U.S. Health and Human Services regulations, "Nondiscrimination on the Basis of Age in Programs or Activities Receiving Federal Financial Assistance," 45 C.F.R. part 90, and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees to refrain from discrimination against present and prospective employees for reason of age. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. IV. Disabilities. In accordance with section 504 of the Rehabilitation Act of 1973, as amended, 29 U.S.C. §794,the Americans with Disabilities Act of 1990,as amended,42 U.S.C. § 12101 et seq.,the Architectural Barriers Act of 1968, as amended, 42 U.S.C. §4151 et seq., and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against individuals on the basis of disability. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue. 10. CLEAN AIR ACT AND FEDERAL WATER POLLUTION CONTROL ACT (Applies to Subcontracts OVER$150,000 at Every Tier) The Contractor agrees: 1) It will not use any violating facilities; 2) It will report the use of facilities placed on or likely to be placed on the U.S. EPA"List of Violating Facilities;" 3) It will report violations of use of prohibited facilities to FTA; and 4) It will comply with the inspection and other requirements of the Clean Air Act, as amended, (42 U.S.C. §§7401 —7671q); and the Federal Water Pollution Control Act as amended, (33 U.S.C. §§ 1251-1387). 5) The Contractor also agrees to include these requirements in each subcontract exceeding $150,000 financed in whole or in part with Federal assistance provided by FTA. 10. CONTRACT WORK HOURS AND SAFETY SAN DARDS ACT (Applies to Subcontracts at Every Tier) For all contracts in excess of $100,000 that involve the employment of mechanics or laborers, the Contractor shall comply with the Contract Work Hours and Safety Standards Act(40 U.S.C. §§3701-3708), as supplemented by the DOL regulations at 29 C.F.R. part 5. Under 40 U.S.C. § 3702 of the Act, the Contractor shall compute the wages of every mechanic and laborer, including watchmen and guards, on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week.The requirements of 40 U.S.C. §3704 are Sources lel ETA FY18 Comp.Reyes Guide Jot Procurement;1JOT PTA FY18 Master Agreement Generally Applicable Provisions;FTA Rest Thoraces Procurement Oct 2016 Revised 1-4-19 FCP-7 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) applicable to construction work and provide that no laborer or mechanic be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchase of supplies or materials or articles ordinarily available on the open market, or to contracts for transportation or transmission of intelligence. In the event of any violation of the clause set forth herein,the Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition,the Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory,to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of this clause in the sum of$10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by this clause. The FTA shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the Contractor or subcontractor under any such contract or any other Federal contract with the same prime Contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime Contractor, such sums as may be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in this section. The Contractor or subcontractor shall insert in any subcontracts the clauses set forth in this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts.The prime Contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in this agreement. Contract Work Hours and Safety Standards for Awards Not Involving Construction The Contractor shall comply with all federal laws, regulations, and requirements providing wage and hour protections for non-construction employees, in accordance with 40 U.S.C. § 3702, Contract Work Hours and Safety Standards Act, and other relevant parts of that Act, 40 U.S.C. § 3701 et seq., and U.S. DOL regulations, "Labor Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted Construction (also Labor Standards Provisions Applicable to Non-construction Contracts Subject to the Contract Work Hours and Safety Standards Act),"29 C.F.R. part 5. The Contractor shall maintain payrolls and basic payroll records during the course of the work and shall preserve them for a period of three (3) years from the completion of the contract for all laborers and mechanics, including guards and watchmen,working on the contract. Such records shall contain the name and address of each such employee, social security number, correct classifications, hourly rates of wages paid, daily and weekly number of hours worked, deductions made, and actual wages paid. Such records maintained under this paragraph shall be made available by the Contractor for inspection, copying, or transcription by authorized representatives of the FTA and the Department of Labor, and the Contractor will permit such representatives to interview employees during working hours on the job. The contractor shall require the inclusion of the language of this clause within subcontracts of all tiers. 12. COPELAND ANTI-KICKBACK ACT For all construction contracts >$2,000, the Contractor agrees to comply with the Copeland "Anti Kickback" Act(Copeland Act) provisions. The Contractor shall also comply with the Copeland"Anti-Kickback"Act(40 U.S.C. § 3145), as supplemented by DOL regulations at 29 C.F.R. part 3, "Contractors and Subcontractors on Public Building or Public Work Financed in Whole or in part by Loans or Grants from the United States." Sources re%:ETA 1718(cmp.ltewew Guide for Procurement:DOT FTA FY 18 Master Agreement Generally Applicable Provtslonr;PTA Rest Practices Procurement Ocl.2016 Revised 1-4-19 FCP-8 k,4:7 161311 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) The Contractor is prohibited from inducing, by any means, any person employed in the construction, completion, or repair of public work,to give up any part of the compensation to which he or she is otherwise entitled. The Copeland "Anti Kickback"Act (Copeland Act) is divided into two sections. Section 1 of the Copeland "Anti-Kickback" Act, at 18 U.S.C. § 874, prohibits anyone from inducing, by any means, any person employed on construction, prosecution,completion,or repair of a federally assisted building or work,to give up any part of his or her compensation to which he or she is otherwise entitled. Section 2 of that Act, at 40 U.S.C. § 3145, and implementing DOL regulations, "Contractors and Subcontractors on Public Building or Public Work Financed in Whole or in part by Loans or Grants from the United States," 29 C.F.R. part 3, imposes record keeping requirements on all third party contracts for construction, alteration, or repair exceeding $2,000. Under Appendix II to 2 C.F.R. part 200—Contract Provisions for Non-Federal Entity Contracts Under Federal Awards, recipients' third party contracts must include a provision for compliance with the Copeland "Anti-Kickback"Act, as amended, and implementing DOL regulations. 13. DAVIS BACON ACT For all prime construction, alteration or repair contracts in excess of$2,000 awarded by FTA,the Contractor shall comply with the Davis-Bacon Act. Under 49 U.S.C. § 5333(a), prevailing wage protections apply to laborers and mechanics employed on FTA assisted construction, alteration, or repair projects. The Contractor will comply with the Davis-Bacon Act,40 U.S.C.§§3141-3144,and 3146-3148 as supplemented by Department of Labor regulations (29 C.F.R. part 5, "Labor Standards Provisions Applicable to Contracts Governing Federally Financed and Assisted Construction"). In accordance with the statute, the Contractor shall pay wages to laborers and mechanics at a rate not less than the prevailing wages specified in a wage determination made by the Secretary of Labor. In addition, the Contractor agrees to pay wages not less than once a week. (1) Minimum wages- (i)All laborers and mechanics employed or working upon the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account(except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act(29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may be alleged to exist between the contractor and such laborers and mechanics. Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Davis-Bacon Act on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (1)(iv) of this section; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period. Such laborers and mechanics shall be paid the appropriate wage rate and fringe benefits on the wage determination for the classification of work actually performed, without regard to skill, except as provided in 29 CFR Part 5.5(a)(4). Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein: Provided, that the employer's payroll records accurately set forth the time spent in each classification in which work is performed. The wage determination (including any additional classifications and wage rates conformed under paragraph (1)(ii) of this section) and the Davis-Bacon poster(WH-1321) shall be posted at all times by the contractor and its subcontractors at the site of the work in a prominent and accessible place where it can be easily seen by the workers. (ii)(A)The contracting officer shall require that any class of laborers or mechanics, including helpers,which Sources re( FTA FYI N Comp.Review Guide is,Pracuremem;DOT/TA FY 18 Master Agreement Generally App/reahle Provisions,FTA Best Practices Procurement Oct.20/6 Revised 1-4-19 FCP-9 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The contracting officer shall approve an additional classification and wage rate and fringe benefits therefore only when the following criteria have been met: (1) Except with respect to helpers as defined as 29 CFR 5.2(n)(4), the work to be performed by the classification requested is not performed by a classification in the wage determination; and (2)The classification is utilized in the area by the construction industry; and (3)The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination; and (4)With respect to helpers as defined in 29 CFR 5.2(n)(4), such a classification prevails in the area in which the work is performed. (B) If the contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the contracting officer agree on the classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour Division, Employment Standards Administration, U.S. Department of Labor, Washington, DC 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (C) In the event the contractor, the laborers or mechanics to be employed in the classification or their representatives, and the contracting officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the contracting officer shall refer the questions, including the views of all interested parties and the recommendation of the contracting officer, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (D)The wage rate(including fringe benefits where appropriate)determined pursuant to paragraphs(a)(1)(ii) (B)or(C)of this section, shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification. (iii) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate,the contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof. (iv) If the contractor does not make payments to a trustee or other third person,the contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program, Provided, That the Secretary of Labor has found, upon the written request of the contractor, that the applicable standards of the Davis-Bacon Act have been met. The Secretary of Labor may require the contractor to set aside in a separate account assets for the meeting of obligations under the plan or program. (v)(A)The contracting officer shall require that any class of laborers or mechanics which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The contracting officer shall approve an additional classification and wage rate and fringe benefits therefor only when the following criteria have been met: 5'ources ref_ETA FY18('amp.Review Guide for Procurement;DOT PTA FY18 Master Agreement Generally Applicable Provisions;FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-10 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS(FTA) (1)The work to be performed by the classification requested is not performed by a classification in the wage determination; and (2) The classification is utilized in the area by the construction industry; and (3)The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination. (B) If the contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the contracting officer agree on the classification and wage rate(including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour Division, Employment Standards Administration, Washington, DC 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (C) In the event the contractor, the laborers or mechanics to be employed in the classification or their representatives, and the contracting officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the contracting officer shall refer the questions,including the views of all interested parties and the recommendation of the contracting officer, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination with 30 days of receipt and so advise the contracting officer or will notify the contracting officer within the 30-day period that additional time is necessary. (D)The wage rate(including fringe benefits where appropriate)determined pursuant to paragraphs(a)(1)(v) (B)or(C)of this section, shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification. (2) Withholding — Collier County shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld from the contractor under this contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to Davis-Bacon prevailing wage requirements,which is held by the same prime contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), all or part of the wages required by the contract, the Collier County may, after written notice to the contractor,sponsor,applicant,or owner,take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased. (3) Payrolls and basic records- (i) Payrolls and basic records relating thereto shall be maintained by the contractor during the course of the work and preserved for a period of three years thereafter for all laborers and mechanics working at the site of the work (or under the United States Housing Act of 1937, or under the Housing Act of 1949, in the construction or development of the project). Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in section 1(b)(2)(B) of the Davis-Bacon Act), daily and weekly number of hours worked, deductions made and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5(a)(1)(iv)that the wages of any laborer or mechanic include the amount Soul ce.P le] FTA FY 18('omp.Review Guide for Proc m emenf 1)OT FTA FY 1R Master Agreement Generally Applicable Provisions;PTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-11 16D11 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) of any costs reasonably anticipated in providing benefits under a plan or program described in section I(b)(2)(B) of the Davis-Bacon Act, the contractor shall maintain records which show that the commitment to provide such benefits is enforceable,that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs. (ii)(A)The contractor shall submit weekly for each week in which any contract work is performed a copy of all payrolls to Collier County for transmission to the Federal Transit Administration. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under section 5.5(a)(3)(i)of Regulations,29 CFR part 5.This information may be submitted in any form desired. Optional Form WH-347 is available for this purpose and may be purchased from the Superintendent of Documents (Federal Stock Number 029-005-00014-1), U.S. Government Printing Office, Washington, DC 20402. The prime contractor is responsible for the submission of copies of payrolls by all subcontractors. (B) Each payroll submitted shall be accompanied by a"Statement of Compliance,"signed by the contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the contract and shall certify the following: (1) That the payroll for the payroll period contains the information required to be maintained under section 5.5(a)(3)(i) of Regulations, 29 CFR part 5 and that such information is correct and complete; (2)That each laborer or mechanic(including each helper,apprentice,and trainee)employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in Regulations, 29 CFR part 3; (3)That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract. (C) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 shall satisfy the requirement for submission of the "Statement of Compliance" required by paragraph (a)(3)(ii)(B) of this section. (D)The falsification of any of the above certifications may subject the contractor or subcontractor to civil or criminal prosecution under section 1001 of title 18 and section 231 of title 31 of the United States Code. (iii)The contractor or subcontractor shall make the records required under paragraph (a)(3)(i)of this section available for inspection, copying, or transcription by authorized representatives of the Federal Transit Administration or the Department of Labor, and shall permit such representatives to interview employees during working hours on the job. If the contractor or subcontractor fails to submit the required records or to make them available, the Federal agency may, after written notice to the contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR 5.12. (4) Apprentices and trainees - (i) Apprentices - Apprentices will be permitted to work at less than the predetermined rate for the work they performed when they are employed pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment Sources ref ETA FY18 Comp.Review Guide for Procurement,DOT PTA FY18 Masser Agreement Generally Applicable Provisions;PTA Bess Practices Procurement Oct.2016 Revised 1-4-19 FCP-12 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) and Training Administration, Bureau of Apprenticeship and Training, or with a State Apprenticeship Agency recognized by the Bureau, or if a person is employed in his or her first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Bureau of Apprenticeship and Training or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice. The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the contractor as to the entire work force under the registered program. Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated above, shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. Where a contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman's hourly rate) specified in the contractor's or subcontractor's registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice's level of progress, expressed as a percentage of the journeymen hourly rate specified in the applicable wage determination. Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator of the Wage and Hour Division of the U.S. Department of Labor determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination. In the event the Bureau of Apprenticeship and Training, or a State Apprenticeship Agency recognized by the Bureau, withdraws approval of an apprenticeship program, the contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved. (ii) Trainees - Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration. The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by the Employment and Training Administration. Every trainee must be paid at not less than the rate specified in the approved program for the trainee's level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed on the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate on the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the Employment and Training Administration shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. In the event the Employment and Training Administration withdraws approval of a training program,the contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved. (iii) Equal employment opportunity-The utilization of apprentices, trainees and journeymen under this part shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended, and 29 CFR part 30. .Sources rel:FTA FY IX Comp.Review Guide for Procurement;DOT PTA FY18 Master Agreement Generally Apphcahle Provisions;FTA Bert Practices Procurement Oct.2016 Revised 1-4-19 FCP-13 16011 1 1 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) (5) Compliance with Copeland Act requirements- The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract. (6) Subcontracts-The contractor or subcontractor shall insert in any subcontracts the clauses contained in 29 CFR 5.5(a)(1) through (10) and such other clauses as the Federal Transit Administration may by appropriate instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all the contract clauses in 29 CFR 5.5. (7) Contract termination: debarment-A breach of the contract clauses in 29 CFR 5.5 may be grounds for termination of the contract, and for debarment as a contractor and a subcontractor as provided in 29 CFR 5.12. (8) Compliance with Davis-Bacon and Related Act requirements-All rulings and interpretations of the Davis-Bacon and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract. (9) Disputes concerning labor standards - Disputes arising out of the labor standards provisions of this contract shall not be subject to the general disputes clause of this contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR parts 5, 6, and 7. Disputes within the meaning of this clause include disputes between the contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives. (10) Certification of eligibility- (i) By entering into this contract, the contractor certifies that neither it(nor he or she) nor any person or firm who has an interest in the contractor's firm is a person or firm ineligible to be awarded Government contracts by virtue of section 3(a) of the Davis-Bacon Act or 29 CFR 5.12(a)(1). (ii) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of section 3(a) of the Davis-Bacon Act or 29 CFR 5.12(a)(1). (iii)The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 U.S.C. 1001. PTA FY18 C'nmpReview Guide Jin Pracuremenl;DOT PTA FY18 Mailer Agreement Generally App/,coble Provisions,PTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-14 16011 EXHIBITIA FEDERAL CONTRACT PROVISIONS (ETA) DOL WAGE DETERMINATION INSERT(COPY AND PASTE)APPLICABLE WAGE DECISION OR DELETE "General Decision Number: FL20190201 02/01/2019 Superseded General Decision Number: FL20180245 State : Florida Construction Type : Building County: Collier County in Florida. BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories) . Note : Under Executive Order (EO) 13658, an hourly minimum wage of $10 . 60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10 . 60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5 . 5 (a) (1) (ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate) . The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5 . 1 (a) (2) - (60) . Additional information on contractor requirements and worker protections under the EO is available at www.dol .gov/whd/govcontracts . Sources ref FTA FY18 Comp,Review Guide for Procurement;WT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Best Practices Procurement Oct.2016 Revised 1-4-19 FCP-15 SAO X6011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Modification Number Publication Date 0 01/04/2019 1 02/01/2019 ASBE0067-003 01/01/2018 Rates Fringes ASBESTOS WORKER/HEAT & FROST INSULATOR $ 27 . 89 15 . 19 ELEC0349-008 09/04/2017 Rates Fringes ELECTRICIAN (Includes Low Voltage Wiring) $ 27 . 55 9. 75 * ELEV0074-001 01/01/2019 Rates Fringes ELEVATOR MECHANIC $ 41 . 17 33 . 705 FOOTNOTE: A. Employer contributions 8% of regular hourly rate to vacation pay credit for employee who has worked in business more than 5 years; Employer contributions 6% of regular hourly rate to vacation pay credit for employee who has worked in business less than 5 years . Paid Holidays : New Year' s Day; Memorial Day; Independence Day; Labor Day; Thanksgiving Day; The Friday after Thanksgiving Day; and Christmas Day. ENGI0487-021 07/01/2016 Rates Fringes OPERATOR: Crane All Cranes 160 Ton Capacity and Over $ 33 . 05 9.20 All Cranes Over 15 Ton Sources ref FTA FY18 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Best Practices Procurement Oct.2016 Revised 1-4-19 FCP-16 C..AO 1 6 1 1 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Capacity $ 32 . 05 9.20 OPERATOR: Forklift $ 23.25 9. 20 OPERATOR: Mechanic $ 32 . 05 9. 20 OPERATOR: Oiler $ 23 . 50 9.20 IRON0397-007 07/01/2018 Rates Fringes IRONWORKER, STRUCTURAL $ 29. 85 15 . 97 IRON0402-001 10/01/2018 Rates Fringes IRONWORKER, ORNAMENTAL $ 23 . 69 12 . 70 * SFFLO821-004 01/01/2019 Rates Fringes SPRINKLER FITTER (Fire Sprinklers) $ 28 . 38 19 . 44 SUFL2014-009 08/16/2016 Rates Fringes CARPENTER $ 18 . 00 0 . 64 CEMENT MASON/CONCRETE FINISHER $ 14 . 85 0 . 60 IRONWORKER, REINFORCING $ 26 . 37 12 . 65 LABORER: Common or General, Including Cement Mason Tending $ 12 . 25 1 . 03 LABORER: Pipelayer $ 14 . 00 1 . 40 OPERATOR: Backhoe/Excavator/Trackhoe $ 22 . 07 8 . 80 OPERATOR: Bulldozer $ 15 . 40 1 . 90 Sources ref:FTA FY18 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Best Practices Procurement Oct 2016 Revised 1-4-19 FCP-17 CM) 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (ETA) OPERATOR: Grader/Blade $ 18 . 97 0 . 00 OPERATOR: Loader $ 14 . 00 1 . 40 OPERATOR: Roller $ 14 . 43 4 . 78 PAINTER: Brush, Roller and Spray $ 14 . 72 2 . 13 PIPEFITTER $ 21 . 36 7 . 93 PLUMBER $ 18 . 01 2 . 88 ROOFER $ 19 . 00 1 . 17 SHEET METAL WORKER, Includes HVAC Duct Installation $ 19 . 10 3 . 27 TILE SETTER $ 18 . 01 0 . 00 TRUCK DRIVER: Dump Truck $ 13 . 22 2 . 12 TRUCK DRIVER: Lowboy Truck $ 14 . 24 0 . 00 WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental . Note : Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017 . If this contract is covered by the E0, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic Sources ref:FTA FY18 Comp.Review Guide for Procurement,DOT FTA FY18 Mosier Agreement Generally Applicable Provisions;FTA Rest Practices Procurement Oct 2016 Revised 1-4-19 FCP-18 CAO 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol .gov/whd/govcontracts . Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5 . 5 (a) (1) (ii) ) . The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type (s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local) , a survey rate (weighted average rate) or a union average rate (weighted union average rate) . Union Rate Identifiers A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example : PLUM0198-005 07/01/2014 . PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers . 0198 indicates the local union number or district council number where applicable, i .e. , Plumbers Local 0198 . The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014 . Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate . Survey Rate Identifiers Sources ref•FTA FY/8 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Best Pracnces Procurement Oct.7016 Revised 1-4-19 FCP-19 x. 6011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates . Example: SULA2012-007 5/13/2014 . SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates . LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier. Survey wage rates are not updated and remain in effect until a new survey is conducted. Union Average Rate Identifiers Classification (s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data . EXAMPLE: UAVG-OH-0010 08/29/2014 . UAVG indicates that the rate is a weighted union average rate. OH indicates the state . The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier. A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based. WAGE DETERMINATION APPEALS PROCESS 1 . ) Has there been an initial decision in the matter? This can be : Sources ref FTA FY18 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions.FTA Best Practices Procurement Oct.7016 Revised 1-4-19 FCP-20 0 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) * an existing published wage determination * a survey underlying a wage determination * a Wage and Hour Division letter setting forth a position on a wage determination matter * a conformance (additional classification and rate) ruling On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2 . ) and 3 . ) should be followed. With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations . Write to: Branch of Construction Wage Determinations Wage and Hour Division U.S . Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 2 . ) If the answer to the question in 1 . ) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1 . 8 and 29 CFR Part 7) . Write to: Wage and Hour Administrator U .S . Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 The request should be accompanied by a full statement of the interested party' s position and by any information (wage payment data, project description, area practice material, etc. ) that the requestor considers relevant to the issue. 3. ) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board) . Write to: Administrative Review Board Sources ref FTA FY18 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Best Practices Procurement Oct 2016 Revised 1-4-19 FCP-21 C.AO 16 011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) U.S . Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 4 . ) All decisions by the Administrative Review Board are final . END OF GENERAL DECISION" Sources ref:FPA FY18 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Best Practices Procurement Oct.20/6 Revised 1-4-19 FCP-22 CAO 1601. 1 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) 14. DEBARMENT AND SUSPENSION (Applies to Subcontracts of Any Tier) The Contractor shall comply and facilitate compliance with U.S. DOT regulations, "Nonprocurement Suspension and Debarment," 2 C.F.R. part 1200, which adopts and supplements the U.S. Office of Management and Budget (U.S. OMB) "Guidelines to Agencies on Governmentwide Debarment and Suspension (Nonprocurement)," 2 C.F.R. part 180. These provisions apply to each contract at any tier of $25,000 or more, and to each contract at any tier for a federally required audit(irrespective of the contract amount), and to each contract at any tier that must be approved by an FTA official irrespective of the contract amount. As such, the Contractor shall verify that its principals, affiliates, and subcontractors are eligible to participate in this federally funded contract and are not presently declared by any Federal department or agency to be: a) Debarred from participation in any federally assisted Award; b) Suspended from participation in any federally assisted Award; c) Proposed for debarment from participation in any federally assisted Award; d) Declared ineligible to participate in any federally assisted Award; e)Voluntarily excluded from participation in any federally assisted Award; or f) Disqualified from participation in ay federally assisted Award. By signing and submitting its bid or proposal, the bidder or proposer certifies as follows: The certification in this clause is a material representation of fact relied upon by the AGENCY. If it is later determined by the AGENCY that the bidder or proposer knowingly rendered an erroneous certification, in addition to remedies available to the AGENCY, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. The bidder or proposer agrees to comply with the requirements of 2 C.F.R. part 180, subpart C, as supplemented by 2 C.F.R. part 1200, while this offer is valid and throughout the period of any contract that may arise from this offer.The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions. 15. DEPARTMENT OF LABOR EEO CONDITIONS The contractor shall comply, with: (a) U.S. DOL regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor,"41 C.F.R. chapter 60, and (b) Executive Order 11246, "Equal Employment Opportunity," as amended by Executive Order 11375, "Amending Executive Order 11246, Relating to Equal Employment Opportunity,"42 U.S.C. § 2000e note. These goals are applicable to all of the contractor's construction work (whether or not it is Federal or federally-assisted) performed in the covered area. Goals for minority participation for each trade: 17.1% Goals for female participation in each trade: 6.9% 16. DISADVANTAGED BUSINESS ENTERPRISE (Applies to Subcontracts at Every Tier) It is the policy of the Collier County Board of County Commissioners (BCC) to ensure that Disadvantaged Business Enterprises (DBE)s are defined in 49 C.F.R. part 26, have an equal opportunity to receive and participate in Department of Transportation (DOT)—assisted contracts. It is also the County's policy to: 1. Ensure nondiscrimination in the award and administration of DOT—assisted contracts; 2. Create a level playing field on which DBEs can compete fairly for DOT-assisted contracts; 3. Ensure that the DBE Program is narrowly tailored in accordance with applicable law; 4. Ensure that only firms that fully meet 49 C.F.R. part 26 eligibility standards are permitted to participate as DBEs; 5. Help remove barriers to the participation of DBEs in DOT assisted contracts; 6. Assist the development of firms that can compete successfully in the market place outside the DBE Program. .Yources ef FTA FY1 R Comp_Review Guide for Procurement DOT PTA FY IR Master Apemen!Generally Applicable Provisions;FTA Be,!Practices Procurement Ocl.2016 Revised 1-4-19 FCP-23 loin ' EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) This Contract is subject to 49 C.F.R. part 26. Therefore, the Contractor must satisfy the requirements for DBE participation as set forth herein. These requirements are in addition to all other equal opportunity employment requirements of this Contract. Contract Assurance The Contractor, subrecipient or subcontractor shall not discriminate on the basis of race, color, national origin, gender identity or sex in the performance of this Contract. The Contractor shall carry out applicable requirements of 49 C.F.R. part 26 in the award and administration of DOT-assisted contracts. Failure by the Contractor to carry out these requirements is a material breach of this Contract,which may result in the termination of this Contract or such other remedy as the COUNTY deems appropriate. DBE Participation For the purpose of this Contract, the COUNTY will accept only DBE's who are: 1. Certified by the Florida Unified Certification Program; 2. An out-of-state firm who has been certified by either a local government, state government or Federal government entity authorized to certify DBE status or an agency whose DBE certification process has received FTA approval; or, 3. Certified by another agency approved by the COUNTY. DBE Participation Goal Collier Area Transit's goal for DBE participation is 1.6%. A separate contract goal has not been established for this procurement. Proposed Submission Each Bidder/Offeror, as part of its submission, shall complete an Anticipated DBE Statement that indicates the percentage and dollar value of the total bid/contract amount to be supplied by Disadvantaged Business Enterprises with whom the Bidder/Offeror intends to contract with for the performance of portions of the work under the Contract. Each Bidder/Offer shall also submit a Bid Opportunity List. Payment The prime contractor agrees to pay each subcontractor under this prime contract for satisfactory performance of its contract no later than 30 days from the receipt of each payment the prime contract receives from the BCC. Retainage If retainage from DBE subcontractors is allowed per the contract, the prime contractor agrees further to return retainage payments to each subcontractor within 30 days after the subcontractors work is satisfactorily completed. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the COUNTY. Monitoring and Enforcement The COUNTY shall monitor the Contractor's DBE compliance during the life of the Contract. It will be the responsibility of the Contractor to submit Subcontractor Payment Reports to the COUNTY with each pay application that summarize the total DBE value of the Contract if DBE participation occurs. These reports shall provide the following details: • DBE utilization established for the Contract; •Total value of expenditures with DBE firms for the period; •The value of expenditures with each DBE firm for the period by race and gender; •Total value of expenditures with DBE firms from inception of the Contract; and • The value of expenditures with each DBE firm from the inception of the Contract by race and gender. Sources ref PTA 1,Y18 Comp.Review Guide for Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-24 CAO 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) The Contractor shall not terminate DBE subcontractor(s)without the COUNTY's prior written consent.The COUNTY may provide such written consent only if the Contractor has good cause to terminate the DBE firm. Before transmitting a request to terminate, the Contractor shall give notice in writing to the DBE subcontractor of its intent to terminate and the reason for the request. The Contractor shall give the DBE five days to respond to the notice and advise of the reasons why it objects to the proposed termination. When a DBE subcontractor is terminated or fails to complete its work on the Contract for any reason, the Contractor shall make good faith efforts to find another DBE subcontractor to substitute for the original DBE and immediately notify the COUNTY in writing of its efforts to replace the original DBE. These good faith efforts shall be directed at finding another DBE to perform at least the same amount of work under the Contract as the DBE that was terminated, to the extent needed to meet the Contract goal established for this procurement. Failure to comply with these requirements will be in accordance with the Sanctions for Violations section below. Recordkeeping The prime contractor must maintain records and documents of payments to DBEs for three years following the performance of the contract. The records will be made available for inspection upon request by any authorized representative of the COUNTY or DOT. This reporting requirement also extends to any certified DBE subcontractor. DBE Program and Directory Information The combined statewide directory, identifying all firms eligible to participate as a certified DBE, may be located at the Florida Department of Transportation website. https://fdotxwp02.dot.state.fl.us/EqualOpportunityOfficeBusinessDirectory/CustomSearch.aspx Additional information on Collier Area Transit's DBE Program can be found at CAT's website http://www.colliergov.net/your-government/divisions-f-r/public-transit-neighborhood-enhancement/our- services-/collier-area-transit-cat/dbe 17. DRUG AND ALCOHOL TESTING The contractor agrees to establish and implement a drug and alcohol testing program that complies with 49 CFR Part 655, produce any documentation necessary to establish its compliance with Part 655, and permit any authorized representative of the United States Department of Transportation or its operating administrations, the Florida Department of Transportation, or the COUNTY, to inspect the facilities and records associated with the implementation of the drug and alcohol testing program as required under 49 CFR Parts 655 and review the testing process. The contractor agrees further to certify and submit annually its compliance with Parts 655, Florida Statute 341.061, and Rule 14-90 Florida Administrative Code before January 20th to the Public Transit & Neighborhood Enhancement Division Director. To certify compliance the contractor shall use the "Substance Abuse Certifications" in the "Annual List of Certifications and Assurances for Federal Transit Administration Grants and Cooperative Agreements," which is published annually in the Federal Register. The certification will also include compliance with its adopted System Safety and Security Program Plan pursuant to Florida Rule Chapter 14-90. 18. EMPLOYEE PROTECTIONS (AWARDS INVOLVING CONSTRUCTION) The Contractor shall comply with U.S. DOL regulations, "Recording and Reporting Occupational Injuries and Illnesses," 29 C.F.R. part 1904; "Occupational Safety and Health Standards," 29 C.F.R. part 1910. 19. ENERGY CONSERVATION (Applies to Subcontracts at Every Tier) The contractor agrees to comply with mandatory standards and policies relating to energy efficiency which are contained in the state energy conservation plan issued in compliance with the Energy Policy and Conservation Act. Sources ref.:ITA FY18 Comp-Review Guide for Pronuemen,DOT PTA FY18 Master Agreement Generally Applicable Provisions,FTA Best Practices Procurement Oct.2016 Revised 1-4-19 FCP-25 1613 11 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) 20. FEDERAL CHANGES Contractor shall at all times comply with all applicable FTA regulations, policies, procedures and directives, including without limitation those listed directly or by reference in the Master Agreement between Purchaser and FTA, as they may be amended or promulgated from time to time during the term of this contract. Contractor's failure to so comply shall constitute a material breach of this contract. 21. FEDERAL PRIVACY ACT REQUIREMENTS Applicability—When a grantee maintains files on drug and alcohol enforcement activities for FTA,and those files are organized so that information could be retrieved by personal identifier,the Privacy Act requirements apply to all contracts except micropurchases ($10,000 or less, except for construction contracts over $2,000) The following requirements apply to the Contractor and its employees that administer any system of records on behalf of the Federal Government under any contract: (1)The Contractor agrees to comply with,and assures the compliance of its employees with,the information restrictions and other applicable requirements of the Privacy Act of 1974, 5 U.S.C. § 552a. Among other things, the Contractor agrees to obtain the express consent of the Federal Government before the Contractor or its employees operate a system of records on behalf of the Federal Government. The Contractor understands that the requirements of the Privacy Act, including the civil and criminal penalties for violation of that Act, apply to those individuals involved, and that failure to comply with the terms of the Privacy Act may result in termination of the underlying contract. (2)The Contractor also agrees to include these requirements in each subcontract to administer any system of records on behalf of the Federal Government financed in whole or in part with Federal assistance provided by FTA. 22. FLY AMERICA(Applies to Subcontracts) The Contractor agrees to comply with the following: a) Definitions. As used in this clause-- • "International air transportation" means transportation by air between a place in the United States and a place outside the United States or between two places both of which are outside the United States. • "United States" means the 50 States, the District of Columbia, and outlying areas. • "U.S.-flag air carrier" means an air carrier holding a certificate under 49 U.S.C. Chapter 411. b) When Federal funds are used to fund travel, Section 5 of the International Air Transportation Fair Competitive Practices Act of 1974(49 U.S.C.40118)(Fly America Act) requires contractors, recipients, and others use U.S.-flag air carriers for U.S. Government-financed international air transportation of personnel (and their personal effects) or property, to the extent that service by those carriers is available. It requires the Comptroller General of the United States, in the absence of satisfactory proof of the necessity for foreign-flag air transportation, to disallow expenditures from funds, appropriated or otherwise established for the account of the United States, for international air transportation secured aboard a foreign-flag air carrier if a U.S.-flag air carrier is available to provide such services. c) If available, the Contractor, in performing work under this contract, shall use U.S.-flag carriers for international air transportation of personnel (and their personal effects) or property. d) In the event that the Contractor selects a carrier other than a U.S.-flag air carrier for international air transportation, the Contractor shall include a statement on vouchers involving such transportation essentially as follows: Sources rel, PTA FY1 R Comp.Review Guide/or Procurement,DOT PTA FY IR Master Agreement Generally Applicable Provwsronsr 1%TA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-26 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Statement of Unavailability of U.S.-Flag Air Carriers International air transportation of persons (and their personal effects) or property by U.S.-flag air carrier was not available or it was necessary to use foreign-flag air carrier service for the following reasons. See FAR§47.403. [State reasons]: e) The Contractor shall include the substance of this clause, including this paragraph (e), in each subcontract or purchase under this contract that may involve international air transportation. 23. INCORPORATION OF FEDERAL TRANSIT ADMINISTRATION (FTA)TERMS (Applies to Subcontracts) The preceding provisions include,in part,certain Standard Terms and Conditions required by DOT,whether or not expressly set forth in the preceding contract provisions. All contractual provisions required by DOT, as set forth in FTA Circular 4220.1 F, are hereby incorporated by reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be deemed to control in the event of a conflict with other provisions contained in this Agreement. The Contractor shall not perform any act, fail to perform any act, or refuse to comply with any COUNTY requests which would cause the COUNTY to be in violation of the FTA terms and conditions. 24. ITS STANDARDS Section 5206(e) of the Transportation Equity Act for the 21st Century, Public Law 105-178, 112 Stat. 547, pertaining to conformance with the National Intelligent Transportation Systems Architecture and Standards. All ITS projects funded with Mass Transit Funds from the Highway Trust Funds shall use applicable ITS standards and interoperability tests that have been officially adopted through rulemaking by the United States Department of Transportation (US DOT). 25. LOBBYING Contractors who apply or bid for an award of $100,000 or more shall file the certification required by 49 CFR part 20, "New Restrictions on Lobbying." Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. Each tier shall also disclose the name of any registrant under the Lobbying Disclosure Act of 1995 who has made lobbying contacts on its behalf with non-Federal funds with respect to that Federal contract,grant or award covered by 31 U.S.C. 1352. Such disclosures are forwarded from tier to tier up to the recipient. 26. NO FEDERAL GOVERNMENT OBLIGATION TO THIRD PARTIES BY USE OF A DISCLAIMER The Contractor shall acknowledge and agree that, notwithstanding any concurrence by the Federal Government in or approval of the solicitation or award of the underlying Contract, absent the express written consent by the Federal Government, the Federal Government is not a party to this Contract and shall not be subject to any obligations or liabilities to the Recipient, Contractor or any other party (whether or not a party to that contract)pertaining to any matter resulting from the underlying Contract.The Contractor agrees to include the above clause in each subcontract financed in whole or in part with Federal assistance provided by the FTA. It is further agreed that the clause shall not be modified, except to identify the subcontractor who will be subject to its provisions 27. PRE-AWARD AND POST DELIVERY AUDITS OF ROLLING STOCK PURCHASES The Contractor agrees to comply with 49 U.S.C. §5323(m)and FTA's implementing regulation at 49 C.F.R. part 663. The Contractor shall comply with the Buy America certification(s) submitted with its proposal/bid. The Contractor agrees to participate and cooperate in any pre-award and post-delivery audits performed pursuant to 49 C.F.R. part 663 and related FTA guidance. Sources ref PTA FY 18 Comp.Review Guide/or Procurement DOT PTA FY18 Master Agreement Generally Applicable Provisions.FTA Rest Pt ocbces Procurement Oct 2016 Revised 1-4-19 FCP-27 161311 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) 28. PATENT RIGHTS, RIGHTS IN DATA AND COPYRIGHTS REQUIREMENTS (Applies to Subcontracts at Every Tier) Intellectual Property Rights This project is funded through a Federal award with FTA for experimental, developmental, or research work purposes. As such, certain Patent Rights and Data Rights apply to all subject data first produced in the performance of this Contract. The Contractor shall grant the COUNTY intellectual property access and licenses deemed necessary for the work performed under this Agreement and in accordance with the requirements of 37 C.F.R. part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by FTA or U.S. DOT.The terms of an intellectual property agreement and software license rights will be finalized prior to execution of this Agreement and shall, at a minimum, include the following restrictions: Except for its own internal use, the Contractor may not publish or reproduce subject data in whole or in part, or in any manner or form, nor may the Contractor authorize others to do so, without the written consent of FTA, until such time as FTA may have either released or approved the release of such data to the public. This restriction on publication, however, does not apply to any contract with an academic institution. For purposes of this agreement, the term "subject data" means recorded information whether or not copyrighted, and that is delivered or specified to be delivered as required by the Contract. Examples of "subject data" include, but are not limited to computer software, standards, specifications, engineering drawings and associated lists, process sheets, manuals, technical reports, catalog item identifications, and related information, but do not include financial reports, cost analyses, or other similar information used for performance or administration of the Contract. 1. The Federal Government reserves a royalty-free, non-exclusive and irrevocable license to reproduce, publish, or otherwise use, and to authorize others to use for"Federal Government Purposes," any subject data or copyright described below. For "Federal Government Purposes," means use only for the direct purposes of the Federal Government.Without the copyright owner's consent,the Federal Government may not extend its Federal license to any other party.a.Any subject data developed under the Contract,whether or not a copyright has been obtained; and b. Any rights of copyright purchased by the Contractor using Federal assistance in whole or in part by the FTA. 2. Unless FTA determines otherwise, the Contractor performing experimental, developmental, or research work required as part of this Contract agrees to permit FTA to make available to the public, either FTA's license in the copyright to any subject data developed in the course of the Contract, or a copy of the subject data first produced under the Contract for which a copyright has not been obtained. If the experimental, developmental, or research work, which is the subject of this Contract, is not completed for any reason whatsoever, all data developed under the Contract shall become subject data as defined herein and shall be delivered as the Federal Government may direct. 3. Unless prohibited by state law, upon request by the Federal Government, the Contractor agrees to indemnify, save, and hold harmless the Federal Government, its officers, agents, and employees acting within the scope of their official duties against any liability, including costs and expenses, resulting from any willful or intentional violation by the Contractor of proprietary rights, copyrights, or right of privacy, arising out of the publication, translation, reproduction, delivery, use, or disposition of any data furnished under that contract. The Contractor shall be required to indemnify the Federal Government for any such liability arising out of the wrongful act of any employee, official, or agents of the Federal Government. 4. Nothing contained in this clause on rights in data shall imply a license to the Federal Government under any patent or be construed as affecting the scope of any license or other right otherwise granted to the Federal Government under any patent. 5. Data developed by the Contractor and financed entirely without using Federal assistance provided by the Federal Government that has been incorporated into work required by the underlying Contract is exempt Sources ref.PTA FY1 R('omp.Review Guide for Procurement-,1)OT FTA FY18 Master Agreement Generally Applicable Provisions;FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-28 1613 11 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) from the requirements herein, provided that the Contractor identifies those data in writing at the time of delivery of the Contract work. 6. The Contractor agrees to include these requirements in each subcontract for experimental, developmental, or research work financed in whole or in part with Federal assistance. 29. PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS OR RELATED ACTS (Applies to subcontracts at every tier) (i) The Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 U.S.C. § 3801 et seq. and U.S. DOT regulations, "Program Fraud Civil Remedies,"49 C.F.R. Part 31, apply to its actions pertaining to this Project. Upon execution of the underlying contract, the Contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or the FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, the Contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification, the Federal Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act of 1986 on the Contractor to the extent the Federal Government deems appropriate. (ii)The Contractor also acknowledges that if it makes,or causes to be made, a false,fictitious, or fraudulent claim, statement, submission, or certification to the Federal Government under a contract connected with a project that is financed in whole or in part with Federal assistance originally awarded by FTA under the authority of 49 U.S.C. chapter 53, the Government reserves the right to impose the penalties of 18 U.S.C. §1001 and 49 U.S.C.§5323(1)on the Contractor,to the extent the Federal Government deems appropriate. (iii) The Contractor agrees to include the above two clauses in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions. 30. PROVISIONS FOR RESOLTION OF DISPUTES, BREACHES, OR OTHER LITIGATION BREACHES AND DISPUTE RESOLUTION (Applies to subcontracts at every tier over$150,000) Disputes-Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of the vendor with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached during negotiations to OWNER for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of the vendor with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached at mediation to OWNER'S board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stats. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida,which courts have sole and exclusive jurisdiction on all such matters. 31. PROMPT PAYMENT AND RETURN OF RETAINAGE (49 C.F.R. part 26) Prompt Payment The prime contractor agrees to pay each subcontractor under this prime contract for satisfactory performance of its contract no later than 30 days from the receipt of each payment the prime contract receives from the BCC. S'ourcea rel':FTA FY18 Comp-Review Guide for Procurement,DOT FTA FY18 Master Agreement Generally Applicable Provisions,PTA Best Practices Procurement Oct.2016 Revised 1-4-19 FCP-29 CAU 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) Retainage If retainage from DBE subcontractors is allowed per the contract, the prime contractor agrees further to return retainage payments to each subcontractor within 30 days after the subcontractors work is satisfactorily completed. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the COUNTY. 32. RECYCLED PRODUCTS (Applies to subcontracts at every tier for purchases$10,000 or more of one of these items in a fiscal year, or when the cost of such items purchased during the previous fiscal year was$10,000.) Recovered Materials.The Contractor agrees to provide a preference for those products and services that conserve natural resources, protect the environment, and are energy efficient by complying with and facilitating compliance with Section 6002 of the Resource Conservation and Recovery Act, as amended, 42 U.S.C. § 6962, and U.S. Environmental Protection Agency (U.S. EPA), "Comprehensive Procurement Guideline for Products Containing Recovered Materials,"40 C.F.R. part 247. 33. SAFE OPERATION OF MOTOR VEHICLES (Applied to Subcontracts at Every Tier) Seat Belt Use The Contractor is encouraged to adopt and promote on-the-job seat belt use policies and programs for its employees and other personnel that operate company-owned vehicles, company-rented vehicles, or personally operated vehicles. The terms"company-owned" and"company-leased" refer to vehicles owned or leased either by the Contractor or AGENCY. Distracted Driving The Contractor agrees to adopt and enforce workplace safety policies to decrease crashes caused by distracted drivers, including policies to ban text messaging while using an electronic device supplied by an employer, and driving a vehicle the driver owns or rents, a vehicle Contactor owns, leases, or rents, or a privately-owned vehicle when on official business in connection with the work performed under this agreement. 34. SCHOOL BUS OPERATIONS The contractor agrees to comply with 49 U.S.C. 5323(f), and 49 C.F.R. part 604, and not engage in school bus operations using federally funded equipment or facilities in competition with private operators of school buses, except as permitted under: i. Federal transit laws, specifically 49 U.S.C. § 5323(f); ii. FTA regulations, "School Bus Operations,"49 C.F.R. part 605; iii. Any other Federal School Bus regulations; or iv. Federal guidance, except as FTA determines otherwise in writing. If Contractor violates this School Bus Agreement, FTA may: i. Bar the Contractor from receiving Federal assistance for public transportation; or ii. Require the contractor to take such remedial measures as FTA considers appropriate. When operating exclusive school bus service under an allowable exemption, the contractor may not use federally funded equipment, vehicles, or facilities. The Contractor should include the substance of this clause in each subcontract or purchase under this contract that may operate public transportation services. 35. SEISMIC SAFETY REQUIREMENTS (Applies to Subcontractors) The contractor agrees that any new building or addition to an existing building will be designed and constructed in accordance with the standards for Seismic Safety required in Department of Transportation Seismic Safety Regulations 49 CFR Part 41 and will certify to compliance to the extent required by the regulation. The contractor also agrees to ensure that all work performed under this contract including work Sources ref:PTA FY18('omp.Review Guide for Procurement;U(1T FTA FY18 Master Agreement Generally Ap/dicahle Provisions;FTA Rest Practices Procurement Oct 2016 Revised 1-4-19 FCP-30 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) performed by a subcontractor is in compliance with the standards required by the Seismic Safety Regulations and the certification of compliance issued on the project. 36. SPECIAL DEPT. OF LABOR EEO CLAUSE FOR CONSTRUCTION CONTRACTS (Applies to Contracts and Subcontracts >$10,000) Equal Employment Opportunity Requirements for Construction Activities.The Contractor will comply,when undertaking "construction"as recognized by the U.S. Department of Labor(U.S. DOL), with: (a) U.S. DOL regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor,"41 C.F.R. chapter 60, and (b) Executive Order No. 11246, "Equal Employment Opportunity in Federal Employment," September 24, 1965, 42 U.S.C. §2000e note (30 Fed. Reg. 12319, 12935), as amended by any later Executive Order that amends or supersedes it, referenced in 42 U.S.C. §2000e note. [(FTA Master Agreement(24), 10-1-2017;§ 12.d(3)] 37. SPECIAL NOTIFICATION REQUIREMENTS FOR STATES (STATE GRANT PROVISIONS) Equal Employment Opportunity:The Contractor shall not discriminate against any employee or applicant for employment because of race, age, creed, color, sex or national origin. The Agency will take affirmative action to ensure that applicants are employed, and that employees are treated during employment,without regard to their race, age, creed, color, sex, or national origin. Such action shall include, but not be limited to,the following: Employment upgrading,demotion,or transfer; recruitment or recruitment advertising;layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Contractors must insert a similar provision in all subcontracts, except subcontracts for standard commercial supplies or raw materials. Interest of Members of Congress: No member of or delegate to the Congress of the United States shall be admitted to any share or part of this contract or to any benefit arising there from. Interest of Public Officials: No member, officer, or employee of the public body or of a local public body during his tenure or for two years thereafter shall have any interest, direct or indirect, in this contract or the proceeds thereof. For purposes of this provision, public body shall include municipalities and other political subdivisions of States; and public corporations, boards, and commissions established under the laws of any State. Lobbying: No funds received pursuant to this Agreement may be expended for lobbying the Legislature, the judicial branch or a state agency. Restrictions, Prohibits, Controls, and Labor Provisions: During the performance of this contract, the following provisions are to be included in each subcontract entered into pursuant to this contract: a)A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, Florida Statutes for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. b) In accordance with Section 287.134, Florida Statutes, an entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building Sources ref FTA FY18 Comp.Review Guide Jot Procureinem;DOT ETA FYI R Master Agreement(feet ally Applicable Provisions;FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-31 161311 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity. c) An entity or affiliate who has had its Certificate of Qualification suspended, revoked, denied or have further been determined by the Department to be a non-responsible contractor may not submit a bid or perform work for the construction or repair of a public building or public work on a contract with the County. d) Neither the County nor any of its contractors or their subcontractors shall enter into any contract, subcontract or arrangement in connection with the Project or any property included or planned to be included in the Project in which any member, officer or employee of the County or the locality during tenure or for two (2) years thereafter has any interest, direct or indirect. If any such present or former member, officer or employee involuntarily acquires or had acquired prior to the beginning of tenure any such interest, and if such interest is immediately disclosed to the County, the County, with prior approval of the Florida Department of Transportation, may waive the prohibition contained in this paragraph provided that any such present member, officer or employee shall not participate in any action by the Agency or the locality relating to such contract, subcontract or arrangement. The County shall insert in all contracts entered into in connection with the Project or any property included or planned to be included in any Project, and shall require its contractors to insert in each of their subcontracts, the following provision: "No member, officer or employee of the Agency or of the locality during his tenure or for 2 years thereafter shall have any interest, direct or indirect, in this contract or the proceeds thereof." Inspector General Cooperation.The Parties agree to comply with Section 20.055(5), Florida Statutes,for the inspector general to have access to any records,data and other information deemed necessary to carry out his or her duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5), Florida Statutes. Employment Eligibility (Using E-Verify) a) Shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the Agency during the term of the Agreement; and b) Shall expressly require any contractors and subcontractors performing work or providing services pursuant to the Agreement to likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the contractor or subcontractor during the Agreement term. 38. TERMINATION PROVISIONS (Applies to Subcontracts at Every Tier in Excess of$10,000) All contracts in excess of $10,000 must address termination for cause and for convenience by the non- Federal entity including the manner by which it will be effected and the basis for settlement. i. Termination for Convenience(General Provision)The COUNTY may terminate this contract, in whole or in part, at any time by written notice to the Contractor when it is in the COUNTY's best interest. The Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the COUNTY to be paid the Contractor. If the Contractor has any property in its possession belonging to the COUNTY, the Contractor will account for the same, and dispose of it in the manner the COUNTY directs. Sources rel:ETA FYI F Comp.Review Guide for Procurement;DOT FTA FY18 Masser Agreement Generally Applicable Provisions,ETA Bess Practices Procurement Oct 2016 Revised 1-4-19 FCP-32 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) ii. Termination for Default [Breach or Cause] (General Provision) If the Contractor does not deliver supplies in accordance with the contract delivery schedule, or, if the contract is for services,the Contractor fails to perform in the manner called for in the contract, or if the Contractor fails to comply with any other provisions of the contract, the COUNTY may terminate this contract for default. Termination shall be effected by serving a notice of termination on the contractor setting forth the manner in which the Contractor is in default. The contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner of performance set forth in the contract. If it is later determined by the COUNTY that the Contractor had an excusable reason for not performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the control of the Contractor, the COUNTY,after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. iii. Opportunity to Cure (General Provision) The COUNTY in its sole discretion may, in the case of a termination for breach or default, allow the Contractor [an appropriately short period of time] in which to cure the defect. In such case, the notice of termination will state the time period in which cure is permitted and other appropriate conditions If Contractor fails to remedy to COUNTY's satisfaction the breach or default of any of the terms, covenants, or conditions of this Contract within [ten (10) days] after receipt by Contractor of written notice from COUNTY setting forth the nature of said breach or default, COUNTY shall have the right to terminate the Contract without any further obligation to Contractor. Any such termination for default shall not in any way operate to preclude COUNTY from also pursuing all available remedies against Contractor and its sureties for said breach or default. iv. Waiver of Remedies for any Breach In the event that COUNTY elects to waive its remedies for any breach by Contractor of any covenant,term or condition of this Contract, such waiver by COUNTY shall not limit the COUNTY's remedies for any succeeding breach of that or of any other term, covenant, or condition of this Contract. v. Termination for Convenience(Professional or Transit Service Contracts)The COUNTY, by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the COUNTY shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination. vi. Termination for Default(Supplies and Service) If the Contractor fails to deliver supplies or to perform the services within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the COUNTY may terminate this contract for default. The COUNTY shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. The Contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner or performance set forth in this contract. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the COUNTY. vii. Termination for Default(Transportation Services) If the Contractor fails to pick up the commodities or to perform the services, including delivery services, within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the COUNTY may terminate this contract for default. The COUNTY shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of default. The Contractor will only be paid the contract price for services performed in accordance with the manner of performance set forth in this contract. Sources ref:PTA FY18 Comp_Review Guide far Procurement;DOT PTA FY18 Master Agreement Generally Applicable Provisions,ETA Best Practices Procurement Oct.1016 Revised 1-4-19 FCP-33 X6011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) If this contract is terminated while the Contractor has possession of COUNTY goods, the Contractor shall, upon direction of the COUNTY, protect and preserve the goods until surrendered to the COUNTY or its agent. The Contractor and COUNTY shall agree on payment for the preservation and protection of goods. Failure to agree on an amount will be resolved under the Dispute clause. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the COUNTY. viii. Termination for Default(Construction) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the COUNTY may terminate this contract for default. The COUNTY shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the COUNTY may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the COUNTY resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the COUNTY in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if- a. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the COUNTY, acts of another Contractor in the performance of a contract with the COUNTY, epidemics, quarantine restrictions, strikes, freight embargoes; and b. The contractor, within [10] days from the beginning of any delay, notifies the COUNTY in writing of the causes of delay. If in the judgment of the COUNTY, the delay is excusable, the time for completing the work shall be extended. The judgment of the COUNTY shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the COUNTY. ix. Termination for Convenience or Default(Architect and Engineering)The COUNTY may terminate this contract in whole or in part, for the COUNTY's convenience or because of the failure of the Contractor to fulfill the contract obligations. The COUNTY shall terminate by delivering to the Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination. Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. If the termination is for the convenience of the COUNTY, the Contracting Officer shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services. Sources ret:FTA FY18('omp.Review Guide Jo,Promiremem;AOT FTA FY18 Masser Agreement Generally Applicable Provisions.PTA Rest/'racnces Procurement Oct 2016 Revised 1-4-19 FCP-34 1 601 1 EXHIBIT LA FEDERAL CONTRACT PROVISIONS (FTA) If the termination is for failure of the Contractor to fulfill the contract obligations,the COUNTY may complete the work by contact or otherwise and the Contractor shall be liable for any additional cost incurred by the COUNTY. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the COUNTY. x. Termination for Convenience of Default (Cost-Type Contracts) The COUNTY may terminate this contract, or any portion of it, by serving a notice or termination on the Contractor. The notice shall state whether the termination is for convenience of the COUNTY or for the default of the Contractor. If the termination is for default,the notice shall state the manner in which the contractor has failed to perform the requirements of the contract. The Contractor shall account for any property in its possession paid for from funds received from the COUNTY,or property supplied to the Contractor by the COUNTY. If the termination is for default, the COUNTY may fix the fee, if the contract provides for a fee, to be paid the contractor in proportion to the value, if any, of work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the COUNTY and the parties shall negotiate the termination settlement to be paid the Contractor. If the termination is for the convenience of the COUNTY, the Contractor shall be paid its contract close-out costs, and a fee, if the contract provided for payment of a fee, in proportion to the work performed up to the time of termination. If, after serving a notice of termination for default, the COUNTY determines that the Contractor has an excusable reason for not performing, such as strike, fire, flood, events which are not the fault of and are beyond the control of the contractor, the COUNTY, after setting up a new work schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. 39. TRANSIT EMPLOYEE PROTECTIVE ARRANGEMENTS The Contractor agrees to comply with the following protective arrangement of 49 U.S.C. § 5333(b): i. U.S. DOL Certification. Under this Contract or any Amendments thereto that involve public transportation operations that are supported with federal assistance, a certification issued by U.S. DOL is a condition of the Contract. ii. Special Warranty. When the Contract involves public transportation operations and is supported with federal assistance appropriated or made available for 49 U.S.C. § 5311, U.S. DOL will provide a Special Warranty for its Award, including its Award of federal assistance under the Tribal Transit Program.The U.S. DOL Special Warranty is a condition of the Contract. iii. Special Arrangements. The conditions of 49 U.S.C. § 5333(b) do not apply to Contractors providing public transportation operations pursuant to 49 U.S.C. § 5310. FTA reserves the right to make case-by- case determinations of the applicability of 49 U.S.C. § 5333(b)for all transfers of funding authorized under title 23, United States Code (flex funds), and make other exceptions as it deems appropriate, and, in those instances, any special arrangements required by FTA will be incorporated herein as required. Sources ref ETA FYI B Comp.Review Guide fm,Prncuremem,DOT hTA FYI R Master Agreement Generally Applicable Pravrsron.r:FTA Best Pi acaces Procurement Oct.2016 Revised 1-4-19 FCP-35 111 111, .I i 1 6 3 1 1 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) FEDERAL EMERGENCY MANAGEMENT AGENCY PUBLIC ASSISTANCE STATUTORY AUTHORITY a. 2 C.F.R. Part 200 Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards b. 44 C.F.R. Part 206 c.The Robert T. Stafford Disaster Relief and Emergency Assistance Act, Public Law 93-288, as amended, 42 U.S.C. 5121 et seq., and Related Authorities d. FEMA Public Assistance Program and Policy Guide, 2017 (in effect for incidents declared on or after April 1, 2017) Contracting with small and minority businesses,women's business enterprises, and labor surplus area firms §200.321 (a) The Solicitor must take all necessary affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whenever possible. (b) Affirmative steps must include: (1) Placing qualified small and minority businesses and women's business enterprises on solicitation lists; (2) Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; (3) Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; (4) Establishing delivery schedules,where the requirement permits,which encourage participation by small and minority businesses, and women's business enterprises; (5) Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce; and (6) Requiring the prime contractor, if subcontracts are to be let, to take the affirmative steps listed in paragraphs (1)through (5) of this section. DHS Seal, Logo, and Flags: The contractor shall not use the DHS seal(s), logos, crests, or reproductions of flags or likenesses of DHS agency officials without specific FEMA pre-approval. Equal Employment Opportunity Clause (§60-1.4): Except as otherwise provided under 41 C.F.R. Part 60, all contracts that meet the definition of"federally assisted construction contract" in 41 C.F.R. § 60-1.3 must include the equal opportunity clause provided under 41 C.F.R. § 60- 1.4. During the performance of this contract, the contractor agrees as follows: Som ces ref FTA FY18 Comp.Review Guide for Procurement;DOT PTA FY18 Master Agreement Generally Applicable Promsions;FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-36 16011 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) The contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity,or national origin.Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment, or recruitment advertising; layoff or termination;rates of pay or other forms of compensation; and selection for training, including apprenticeship. The contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. II. The contractor will, in all solicitations or advertisements for employees placed by or on behalf of the contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. III. The contractor will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the contractor's legal duty to furnish information. IV. The contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. V. The contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. VI. The contractor will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. VII. In the event of the contractor's non-compliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be canceled, terminated or suspended in whole or in part and the contractor may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. Sources ref:ETA 1,718 Comp-Review Guide/or Procurement;DOT FTA FY18 Master Agreement Generally Applicable Provisions,FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-37 EXHIBIT I.A FEDERAL CONTRACT PROVISIONS (FTA) VIII. The contractor will include the provisions of paragraphs (1) through (8) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor.The contractor will take such action with respect to any subcontract or purchase order as may be directed by the Secretary of Labor as a means of enforcing such provisions including sanctions for noncompliance: Provided, however, that in the event the contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction,the contractor may request the United States to enter into such litigation to protect the interests of the United States. STATE PROVISIONS Convicted Vendor and Discriminatory Vendors List: Those who have been placed on the convicted vendor list following a conviction for a public entity crime or on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work,may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with a public entity, and may not transact business with any public entity in excess of$25,000.00 for a period of 36 months from the date of being placed on the convicted vendor list or on the discriminatory vendor list. Equal Employment Opportunity: The Contractor shall not discriminate against any employee or applicant for employment because of race, age, creed, color, sex or national origin. The Agency will take affirmative action to ensure that applicants are employed, and that employees are treated during employment,without regard to their race, age, creed, color, sex, or national origin. Such action shall include, but not be limited to, the following: Employment upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Contractors must insert a similar provision in all subcontracts, except subcontracts for standard commercial supplies or raw materials. EVerify: Collier County will not intentionally award County contracts and purchase orders to any vendor who knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 U.S.C. Section 1324 a(e) Section 274A(e) of the Immigration and Nationality Act ("INA"). Collier County may consider the employment by any vendor of unauthorized aliens as a violation of Section 274A (e) of the INA. Such violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be grounds for unilateral termination of the contract by Collier County. This certification is required and is to be signed by an authorized official of the company and submitted prior to release of a purchase order. The Vendor attests that it is fully compliant with all applicable immigration laws (specifically to the 1986 Immigration Act and subsequent Amendment(s)) and agrees to comply with the requirements of the E-Verify system operated by the Department of Homeland Security in partnership with the Social Security Administration. a) Shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the Agency during the term of the Agreement; and b) Shall expressly require any contractors, subcontractors or vendors performing work or providing services pursuant to the Agreement to likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the contractor or subcontractor during the Agreement term. Sources re/:ETA FY IN Comp.Review Guide for Pro.,ement,DOT FTA FYI N Master Agreement Generally Applicable Prow.rtons;FTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-38 16011 EXHIBIT LA FEDERAL CONTRACT PROVISIONS (FTA) Inspector General Cooperation: The Parties agree to comply with Section 20.055(5), Florida Statutes, for the inspector general to have access to any records, data and other information deemed necessary to carry out his or her duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5), Florida Statutes. Lobbying: No funds received pursuant to this Agreement may be expended for lobbying the Legislature, the judicial branch or any state agency. Record Retention: The contractor shall maintain and retain sufficient records demonstrating its compliance with the terms of the Agreement for a period of at least five (5) years after final payment is made and shall allow the County, FDEM, or its designee's access to such records upon request. Reporting: The contractor will provide any information required to comply with the grantor agency requirements and regulations pertaining to reporting. It is important that the contractor is aware of the reporting requirements of the County, as the Federal or State granting agency may require the contractor to provide certain information, documentation, and other reporting in order to satisfy reporting requirements to the granting agency. Sources rc FTA FY18 romp_Review Guide Jot Procurement,DOT PTA FY IN Matter Agreement Generally Applicable Provisions;PTA Rest Practices Procurement Oct.2016 Revised 1-4-19 FCP-39 161311 EXHIBIT LB GRANT CERTIFICATIONS AND ASSURANCES FTA GRANT CERTIFICATIONS AND ASSURANCES THE FOLLOWING DOCUMENTS NEED TO BE RETURNED WITH SOLICIATION DOCUMENTS BY DEADLINE TO BE CONSIDERED RESPONSIVE Paye Certification and Form GCA-2 Certification Regarding Debarment, Suspension,and Other Responsibility Matters- Primary Covered Transactions GCA-3 Certification of Lower-Tier Participants Regarding Debarment, Suspension, and Other Ineligibility and Voluntary Exclusion GCA-4 Collier County Conflict of Interest Certification GCA-5 Anticipated DBE,M/WBE or VETERAN Participation Statement GCA-6 Bid Opportunity List for Commodities and Contractual Services and Professional Consultant Services GCA-7 Buy America Certification GCA-8 Certification Regarding Lobbying GCA-9 Acknowledgement of Grant Terms and Conditions GCA- I (s 16011 REQUIRED FORMS— FTA Grant Certifications and Assurances EXHIBIT LB GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Certification Regarding Debarment,Suspension,and Other Responsibility Matters Primary Covered Transactions (1) The prospective primary participant certifies to the best of its knowledge and belief, that it and its principals: (a) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency; (b) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public(Federal, State or local)transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft,forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (c) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local)with commission of any of the offenses enumerated in paragraph(l)(b)of this certification;and (d) Have not within a three-year period preceding this application/proposal had one or more public transactions(Federal, State or local)terminated for cause or default. (2) Where the prospective primary participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal. Howard L. Wheeler, II General Contractors for Public Transit Construction Name Project Name President 19-7646 Title Project Number Chris-Tel Company of Southwest Florida,Inc., dba Chris-Tel Construction 65-0384539 Firm Tax ID Number N/A DUNS Number 2534-A Edison Avenue Fort Myers, Florida 33901 Street Address, City, State,Zip Signature GCA-2 CHRIS TEL RFQ No.19-7646 General Contractors for Public Transit Construction 58 CONSTRUCTION Cc''O 1 6011 REQUIRED FORMS— FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Certification of Lower-Tier Participants Regarding Debarment, Suspension,and Other Ineligibility and Voluntary Exclusion (1) The prospective Lower-Tier participant certifies to the best of its knowledge and belief, that it and its principals: (a) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency; (b) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public(Federal, State or local)transaction or contract under a public transaction;violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (c) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local)with commission of any of the offenses enumerated in paragraph(1)(b)of this certification;and (d) Have not within a three-year period preceding this application/proposal had one or more public transactions(Federal,State or local)terminated for cause or default. (2) Where the prospective primary participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal. Howard L. Wheeler, II General Contractors for Public Transit Construction Name Project Name President 19-7646 Title Project Number Chris-Tel Company of Southwest Florida,Inc., 65-0384539 dba Chris-Tel Construction Firm Tax ID Number N/A DUNS Number 2534-A Edison Avenue Fort Myers, FL 33901 Street Address,City, State,Zip Signature GCA-3 CHRIS+TEL RFQ No.19-7646 General Contractors for Public Transit Construction 59 CONSTRUCTION 0 1 61311 REQUIRED FORMS— FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Conflict of Interest Certification 19-7646 General Contractors for Public Transit Construction Collier County Solicitation No. 1 Howard L. Wheeler, II ,hereby certify that to the best of my knowledge,neither I nor my spouse, dependent child,general partner, or any organization for which I am serving as an officer, director, trustee,general partner or employee,or any person or organization with whom I am negotiating or have an arrangement concerning prospective employment has a financial interest in this matter. I further certify to the best of my knowledge that this matter will not affect the financial interests of any member of my household. Also,to the best of my knowledge,no member of my household;no relative with whom I have a close relationship; no one with whom my spouse, parent or dependent child has or seeks employment; and no organization with which I am seeking a business relationship nor which I now serve actively or have served within the last year are parties or represent a party to the matter. I also acknowledge my responsibility to disclose the acquisition of any financial or personal interest as described above that would be affected by the matter,and to disclose any interest I,or anyone noted above, has in any person or organization that does become involved in,or is affected at a later date by,the conduct of this matter. Howard L.Wheeler, II Name Signature President August 6, 2019 Position bate Privacy Act Statement Title I of the Ethics in Government Act of 1978 (5 U.S.C. App.), Executive Order 12674 and 5 CFR Part 2634, Subpart I require the reporting of this information.The primary use of the information on this form is for review by officials of The Justice Department to determine compliance with applicable federal conflict of interest laws and regulations. Additional disclosures of the information on this report may be made:(1)to a federal, state or local law enforcement agency if the Justice Department becomes aware of a violation or potential violation of law or regulations;(2)to a court or party in a court or federal administrative proceeding if the government is a party or in order to comply with a judge-issued subpoena;(3)to a source when necessary to obtain information relevant to a conflict of interest investigation or decision;(4)to the National Archives and Records Administration or the General Services Administration in records management inspections;(5) to the Office of Management and Budget during legislative coordination on private relief legislation;and(6) in response to a request for discovery or for the appearance of a witness in a judicial or administrative proceeding, if the information is relevant to the subject matter. This confidential certification will not be disclosed to any requesting person unless authorized by law. See also the OGE/GOVT-2 executive branch- wide Privacy Act system of records. GCA-4 CHRIS TEL RFQ No.19-7646 General Contractors for Public Transit Construction C0 CONSTRUCTION 16011 REQUIRED FORMS— FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER C:OUNTY ANTICIPATED DISADVANTAGED,MINORITY,WOMEN OR VETERAN PARTICIPATION STATEMENT Status Velli be verified. Unveriable statuses mil requue the PRIME to either proiude a revised statement or provide source documentation that ma!idates a status. A. PRIME VENDOR/CONTRACTOR INFORMATION PRIME NAME PRIME.FE.D NUMBER CONTRACT DOLLAR AMOUNT Chris-Tel Comppany of South+nest Florida,Inc., 65-0364539 TBD dba Chris-Id Construction IS THE PMR FLORIDA-CEPTIFED DISAD':AtTAGED, VETEuti y 0 ;THE ACTIVITY OF THIS CONTR.ACT.,: MINORITY OR WOMEN BUSINNESSENTERPRISE? DBE? Y CONSTRUCTION? 0 DBELI BE/WBEI OR HVE A SMALL DISADVANTAGED BUSINESS SA CERTIFICATION FROM THE SMALL BUSINESS MBE' t' 1171 CONSULTATON? V' fit ADMINISTRATION? A SERVICE DISABLED VETERAN' ABE? Y 171 OTHER? Y i 500 8A? 'Y IS Ttf.S SU BMISS ON A REVISION? Y in iF YES,REV SION NUMBER B, IF PRIME HAS SUBCONTRACTOR OR SUPPLIER WHO IS A DISADVANTAGED MINORITY,WOMEN-OWNED,SMALL BUSINESS CONCERN OR SERVICE DISABLED VETERAN,PRIME IS TO COMPLETE THIS NEXT SECTION DBE WWBE SUBCONTRACTOR OR SUPPLIER TYPE OF WORK:OR ETHNICITY CODE SUE/SUPPLIER PERCENT Of CONTRACT VETERAN NAME SPECIALTY {See Below) DOLLAR AMOUNT DOLLARS T BD once avIerded cortrad TOTAL' C. SECTION TO BE COMPLETED BY PRIME VENDOR/CONTRACTOR NAME OF SUBMITTER DATE TITLE OF SUBMITTER Howard L.Wheeler,II August 6,2019 President EMAIL ADDRESS OF PRIME(SUBMITTER) TELEPHONE NUMBER FAX NUMBER hsAheeler@christelconshudion.com 239-226-0500 239-226-0503 NO7E:This mfcemation is used to track and report anbopated DBE or MBE participation in federal r-furrded contracts..The antiopated DBE or MBE amount is voiuntar?,and v411 not become part of the contractual terms.This form must be submitted at time of response to a soicitation. and when awarded a County contract,the prime-svili be asked to update the informationfor the grant compliance files. ETHNICITY WOE Stack American BA. Hispanic A merican Ht, Native American NA Subccnt.Asian American 555 Asian-PacifIC American APA NOn-MinGriti Women NMPAW Other:not of any other group listed 0 D.SECTION TO BE COMPLETED BY COLLIER COUNTY DEPARTMENT NAME COLD ER CONTRACT 4;IIFBiRFP m PO:REQ; GRANT PROGRAM/CONTRACT ACCEPTED BY: — DATE GCA- 5 CHRIS TEL RFQ No.19-7646 General Contractors for Public Transit Construction 61 CONSTRUCTION 161) 11 REQUIRED FORMS- FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CER MICATIONS AND ASSURANCES SID OPPORTUNITY LIST FOR COMMODITIES AND CONTRACTUAL SERVICES AND PROFESSIONAL CONSULTANT SERVICES itt polo'of Corner County Char disadvontoged businesses and navor'y verrdorsas defned in the Code of Federal itegulo+ions(CF?)or iorldc.stoti es IFsj,muse have the onportu,ti'to portiebate on contracts wrth feaem'and/or state grant assistance. Prime 5ontractori,Pr,me Consultant C hr's-Tel Company of Southwest Florida,Inc.,dba Chris-Tel Construction Address and Phone Number: 2534A Edson Avenue Fort Myers,Florida 33901 1(239)226-0503 Procurement Number/Advertisementnumber: 19-7646 General Contractors for Public Transit Construction The lis-below a intended to be a listing of firms that are,or attempting to,participate on the project numbered abcr:e,The list must indude the firm bidding or quoting as prime,as well as subs and suppliers quoting for participation.Prime contractors and consultants must provide information for Numbers 1,2,3,and 4;and,should provide arty information the,have for Numbers 5,6,%,and.B.This form must be subritted with the bid package. 1. Feceral Tara i0 Number. 65-0384539 6.12 DBE II.Annual Gross Receipts 2. Firm Name n,diaw,..>.+a.n«i re...i..,.e.ole.1ce,.+..e. Nor:-DBE Less than S 1 million 3. Phase Number 238-22B-050 Between 5 1-5 million. 4.Adcress 2531-A Maim Pee r re E—t Between$5-10 million. Fort Wets,F L33E01 7. Subcontractor Between 510-15 million Subronsuitant More than 5 15 million 5. yea'Frrm Established. 1988 1. Federal Tax ID Number 6.B DBE a..Annual Gross Receipts 2. Firm Name Non-DBE Less than 51 million 3 Phare Number. Between 5 1-5 million 4.Adcress _Between 5 3-10 million 7. Subcontractor -Between 5 10.15 million B Subconsurtant More than 5 15 million 5. Yea'Firm Established 1. Federal Tax ID Number. 6 EI DBE E. Annual Gross P.ecer-pts 2. Firm Name. Non-DBE Less than 51 million 3. phase Number Between 5 1-5 million 4.Adcress Between 5 5-10 million 7.BSubcontractor Between 5 10`15 million tubconsultant More than$15 million 5. Year Firm Established 1. Federal Tan ID Number' 6.BDBE a_Annual Gross Receipts 2. FaraName Non-DBE Less than 5 1 million 3. Phase Number Between 5 1.5 million 1. .Ad:.crers Between 5 5-10 millior. 7.a Subcontractor Subcansuitant Between 5 10-15 million More than 5 13 million 5. vex Firm Established- GCA -6 CHRIS+TEL RFQ No.19-7646 General Contractors for Public Transit Construction 62 CONSTRUCTION CAv 1601 1 REQUIRED FORMS- FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Federal Transit Administration(FTA) Buy America Certification Steel,Iron or Manufactured Products A bidder or offeror must submit to the FTA recipient the appropriate Buy America certification(below)with all bids or offers on FTA-funded contracts, except those subject to a general waiver. Bids or offers that are not accompanied by a completed Buy America certification must be rejected as nonresponsive. This requirement does not apply to lower tier subcontractors. Certification requirement for procurement of steel,iron,or manufactured products. (SELECT ONE ONLY) Certificate of Compliance with Buy America Requirements The bidder or offeror hereby certifies that it will meet the requirements of 49 U.S.C. 5323(j)(1) and the applicable regulations in 49 C.F.R.Part 661. Date: August 6, 2019 Signature:1-�--- Company: Chris-Tel Company of Southwest Florida, Inc.,dba Chris-Tel Construction — Name: Howard L.Wheeler, II Title: President ❑Certificate of Non-Compliance with Buy America Requirements The bidder or offeror hereby certifies that it cannot comply with the requirements of 49 U.S.C.5323(j),but it may qualify for an exception to the requirement pursuant to 49 U.S.C. 5323(j)(2), as amended, and the applicable regulations in 49 C.F.R.661.7. Date: Signature: — — -- Company: -- — ---- — Name: Title: GCA-7 CHRIS*TEL RFQ No.19-7646 General Contractors for Public Transit Construction C3 CONSTRUCTION CM) 16011 REQUIRED FORMS- FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Certification Regarding Lobbying The undersigned certifies,to the best of his or her knowledge,that: (1)No Federal appropriated funds have been paid or will be paid,by or on behalf of the undersigned,to any person for influencing or attempting to influence an officer or employee of an agency,a Member of Congress,an officer or employee of Congress,or an employee of a Member of Congress in connection with the awarding of any Federal contract,the making of any Federal grant,the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment,or modification of any Federal contract,grant,loan,or cooperative agreement. (2)If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency,a Member of Congress,an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL,'Disclosure Form to Report Lobbying,"in accordance with its instructions. (3) The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including subcontracts,subgrants, and contracts under grants, loans,and cooperative agreements)and that all subrecipients shall certify and disclose accordingly. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31,U.S.C. § 1352(as amended by the Lobbying Disclosure Act of 1995). Any person who fails to file the required certification shall be subject to a civil penalty of not less than$10,000 and not more than$100,000 for each such failure. Chris-Tel Company of Southwest Florida,Inc., The Contractor, dtm Chris-Tel Construction , certifies or affirms the truthfulness and accuracy of each statement of its certification and disclosure, if any. In addition, the Contractor understands and agrees that the provisions of 31 U.S.C. §3801 et seq.,apply to this certification and disclosure,if any. In addition,the Contractor understands and agrees that the provisions of 11.062,Florida Statutes., apply to this certification and disclosure,if any. Signature of Contractor's Authorized Official Howard L.Wheeler, II, President Name of Authorized Official and Title August 6, 2019 Date 02/18 R7 GCA-8 CHRns+TEL RFQ No.19-7646 General Contractors for Public Transit Construction 64 CONSTRUCTION 16011 REQUIRED FORMS- FTA Grant Certifications and Assurances EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Acknowledgement of Terms,Conditions and Grant Clauses Flow Down of Terms and Conditions from the Grant Agreement Subcontracts: If the vendor subcontracts any of the work required under this Agreement, a copy of the signed subcontract must be available to the Department for review and approval. The vendor agrees to include in the subcontract that (1) the subcontractor is bound by the terms of this Agreement, (ii) the subcontractor is bound by all applicable state and federal laws and regulations,and(iii)the subcontractor shall hold the Department and Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement,to the extent allowed and required by law.The recipient shall document in the quarterly report the subcontractor's progress in performing its work under this agreement. For each subcontract,the Recipient shall provide a written statement to the Department as to whether the subcontractor is a minority vendor as defined in Section 288.703,Fla. Stat. Certification On behalf of my firm,I acknowledge,and agree to perform all of the specifications and grant requirements identified in this solicitation document(s). Vendor/Contractor Name Howard L.Wheeler,II,President Date August 6,2019 Authorized Signature Address 2534-A Edison Avenue Fort Myers, Florida 33901 Solicitation/Contract#19-7646 General Contractors for Public Transit Construction GCA-9 CHRIS 4,TEL RFQ No.19-7646 General Contractors for Public Transit Construction 65 CONSTRUCTION AcoRD CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DDIYYYY) 7/22/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT David Kennedy Olin Hill&Associates Inc. PHONE FAX 2804 Del Prado Blvd#107 (,vc.No.Extl:239-945-1900 (A/C,No):239-945-3163 Cape Coral FL 33904 ADDRESS: INSURER(S)AFFORDING COVERAGE _ NAIC# INSURER A:National Trust Insurance Co. 20141 INSURED CHRIS-5 INSURER B:Monroe Guaranty Insurance Co 32506 Chris-Tel Company of Southwest Florida Inc INSURER c:FCCI Insurance Company 10178 dba Chris-Tel Construction; Chris-Tel Energy Inc 2534-A Edison Avenue INSURER D:American Builders Insurance Co 11240 Ft Myers FL 33901 INSURERE: INSURER F: COVERAGES CERTIFICATE NUMBER: 1136909595 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR INSD R TYPE OF INSURANCE ADDL SUBR WVD POLICY NUMBER POLICY EFF POLICY EXP LIMITS (MMIDDIYYYY) (MM/DD/YYYY) A X COMMERCIAL GENERAL LIABILITY GL10004446501 5/1/2019 5/1/2020 EACH OCCURRENCE $1,000,000 DAMAGE TO RENTED CLAIMS-MADE X OCCUR PREMISES(Ea occurrence) $100,000 X Contractual Liab X MED EXP(Any one person) $5,000 X XCU PERSONAL 8 ADV INJURY $1,000,000 GE 'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY X PE� LOC PRODUCTS-COMP/OP AGG $2,000,000 OTHER: $ B AUTOMOBILE LIABILITY CA10002506301 5/1/2019 5/1/2020 COMBINED SINGLE LIMIT $ (Ea accident) 1.000.000 X ANY AUTO BODILY INJURY(Per person) $ X ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS X HIRED AUTOS x AUTO-OWNED (Perry cdent)AMAGE $ C X UMBRELLA LIAB X OCCUR UMB10002506401 5/1/2019 5/1/2020 EACH OCCURRENCE $10,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED X RETENTION$10 000 $ D WORKERS COMPENSATION WCV022589002 10/1/2018 10/1/2019 PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RFQ No. 19-7646 General Contractors for Public Transit Construction. Collier County is named as Additional Insured on a primary and non-contributory basis including ongoing and completed operations on the General Liability,per form#CGL 084. General Liability policy endorsed to include(30)day notice of cancellation with(10)day notice for non-payment of premium. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Collier County Board of County Commissioners 3295 Tamiami Trail East Naples FL 34112 AUTHORIZED REPRESENTATIVE ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16011 COMMERCIAL GENERAL LIABILITY CGL 084(10 13) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU - ONGOING OPERATIONS AND PRODUCTS-COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM SCHEDULE (OPTIONAL) Name of Additional Insured Persons or Organizations (As required by written contract or agreement per Paragraph A. below.) Locations of Covered Operations (As per the written contract or agreement, provided the location is within the "coverage territory".) (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II—Who Is An Insured is amended to include as an additional insured: 1. Any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement in effect during the term of this policy that such person or organization be added as an additional insured on your policy; and 2. Any other person or organization you are required to add as an additional insured under the contract or agreement described in Paragraph 1. above; and 3. The particular person or organization, if any, scheduled above. Such person(s)or organization(s) is an additional insured only with respect to liability for"bodily injury", "property damage"or"personal and advertising injury" occurring after the execution of the contract or agreement described in Paragraph 1. above and caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf in the performance of your ongoing operations for the additional insured; or 3. Your work" performed for the additional insured and included in the"products-completed operations hazard" if such coverage is specifically required in the written contract or agreement. CGL 084(10 13) Includes copyrighted material of the Insurance Services Offices, Inc.with its permission. Page 1 of 3 Copyright 2013 FCCI Insurance Group. 1 6 0 1 1 COMMERCIAL GENERAL LIABILITY CGL 084(10 13) However, the insurance afforded to such additional insured(s)described above: 1. Only applies to the extent permitted by law; 2. Will not be broader than that which you are required by the contract or agreement to provide for such additional insured; 3. Will not be broader than that which is afforded to you under this policy; and 4. Nothing herein shall extend the term of this policy. B. The insurance provided to the additional insured does not apply to"bodily injury", "property damage"or "personal and advertising injury"arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or 2. Supervisory, inspection, architectural or engineering activities. C. This insurance is excess over any other valid and collectible insurance available to the additional insured whether on a primary, excess, contingent or any other basis; unless the written contract or agreement requires that this insurance be primary and non-contributory, in which case this insurance will be primary and non-contributory relative to insurance on which the additional insured is a Named Insured. D. With respect to the insurance afforded to these additional insureds, the following is added to Section III— Limits of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement described in Paragraph A.1.; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. E. Section IV— Commercial General Liability Conditions is amended as follows: The Duties In The Event of Occurrence, Offense, Claim or Suit condition is amended to add the following additional conditions applicable to the additional insured: An additional insured under this endorsement must as soon as practicable: 1. Give us written notice of an "occurrence" or an offense which may result in a claim or"suit" under this insurance, and of any claim or"suit"that does result; 2. Send us copies of all legal papers received in connection with the claim or"suit", cooperate with us in the investigation or settlement of the claim or defense against the "suit", and otherwise comply with all policy conditions; and 3. Tender the defense and indemnity of any claim or"suit"to any provider of other insurance which would cover the additional insured for a loss we cover under this endorsement and agree to make available all such other insurance. However, this condition does not affect Paragraph C. above. CGL 084(10 13) Includes copyrighted material of the Insurance Services Offices, Inc.with its permission. Page 2 of 3 Copyright 2013 FCCI Insurance Group. 16011 COMMERCIAL GENERAL LIABILITY CGL 084(10 13) We have no duty to defend or indemnify an additional insured under this endorsement until we receive from the additional insured written notice of a claim or"suit". F. This endorsement does not apply to any additional insured or project that is specifically identified in any other additional insured endorsement attached to the Commercial General Liability Coverage Form. CGL 084(10 13) Includes copyrighted material of the Insurance Services Offices, Inc.with its permission. Page 3 of 3 Copyright 2013 FCCI Insurance Group.