The URL can be used to link to this page

#19-7589 (CFS Roofing Services, LLC) CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with CFS Roofing Services, LLC ("Contractor") of 12120 Amedicus Lane, Fort Myers, Florida 33907, a Corporation, authorized to do business in the State of Florida, to perform all work ("Work") in connection with NCWRF Operations Building New Roof, Invitation to Bid No. 19-7589 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Wood Environment & Infrastructure Solutions, Inc., the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount"), in accordance with the terms of this Agreement: One Hundred Forty-Seven Thousand Four Hundred Fifty-Five Dollars ($147,455.00). Section 4. Bonds. A. If applicable, the Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit B-1 and B-2, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www.fms.treas.qov/c570/c570.html#certified. Should the Contract Amount be less 1 Construction Services Agreement:Revised 072118 than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall,within five(5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liquidated Damages. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The "Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within ninety (90) calendar days from the Commencement Date (herein "Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for whichit is intended. Contractor shall achieve Final Completion within thirty (30) calendar days after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, Sixty Six Dollars and Sixty-Seven Cents ($66.67) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion. The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty,which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday 2 Construction Services Agreement:Revised 072118 CA or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non-delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed upon, attached hereto and made a part of this Agreement for Solicitation 19-7589 NCWRF Operations Building New Roof. Exhibit A-1: Contractor's Bid Schedule Exhibit A-2: Contractor's Bid Submittal Forms and Addendums Exhibit A-3: Contractor's List of Key Personnel Exhibit B-1: Payment Bond Forms ® Not Applicable Exhibit B-2: Performance Bond Forms ® Not Applicable Exhibit B-3: Insurance Requirem ents Exhibit C: Release and Affidavit Form Exhibit D: Contractor Application for Payment Form Exhibit E: Change Order Form 3 Construction Services Agreement:Revised 072118 t Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions ® Applicable n Not Applicable The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 19-7589 NCWRF Operations Building New Roof. The complete contract documents, including Addendum with attachments, are available on the County's on-line bidding system: https://www.bidsync.com/bidsync-cas/, which the parties agree comprise the final integrated agreement executed by the parties. Sections corresponding to any checked box ( ® ) expressly apply to the terms of this Agreement and are available through the County's on-line bidding. Exhibit J: Technical Specifications (Exhibit K: Permits (Exhibit L: Standard Details ®Exhibit M: Plans and Specifications prepared by: Wood Environment& Infrastructure Solutions, Inc Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, FL c/o Public Utilities Water Division 4370 Mercantile Ave Naples, Florida 34104 Attn: Matthew Fortune, Associate Project Manager Phone: 239-821-6568 Email: Matthew.Fortune a colliercountyfl.gov B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: CFS Roofing Services, LLC 12120 Amedicus Lane Fort Myers, Florida 33907 Attn: David Crowther, President Phone: (239) 561-2600 Email: D.Berendt@cfsroofing.com C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. 4 Construction Services Agreement:Revised 072118 Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor lis t." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreem ent. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. 5 Construction Services Agreement:Revised 072118 Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. 6 Construction Services Agreement:Revised 072118 IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s) indicated below. CONTRACTOR: TWO WITNESSES: CFS Roofing Services, LLC lia"( ------ -- FIRST WITNESS tki. A ,/. C /3(b,a: - I" By:{f Pnnt Name LL [y/ / AQ ,G C-/'a,,,}.k,e✓, 4:01, I A_ 6'f G 1-1 " � Lk- 71 Print Name and Title Date S .OND W 'N SS t.6 i. S IPI P nt Name Date: 1-1(e- -Mr{ ATTEST: OWNER: Crystal K. Kinzel, Clerk of Courts BOARD OF COUNTY COMMISSIONERS &Comptroller — OF COLLIER CO- q •RIDA :/ -;:' :''..- ''. '4 (2).ArdSP) 0. I BY•71),4144 ' .4 • ''' tiO'Ci BY: —mow- ----= Air, •+ Cp. 1 airman iam L. McDaniel iJr. late +A @St 4 t0 C ' P - i atuce l � -C -1 A.prove• =s to F m a Legality: III i kaki L TsCounty Attorney _gZ4V-Name 7 Construction Services Agreement:Revised 072118ell • EXHIBIT A-1: CONTRACTOR'S BID SCHEDULE (FOLLOWING THIS PAGE) 8 Construction Services Agreement: Revised 072118 0 Project No: 19-7589 Project Title: NCWRF Operations Building New Roof Bld Date: 04/25/19 BID SCHEDULE BIDDER: CFS ROOFING SERVICES, LLC 1 General Conditions LS $8,.++' 2 Demolition&Removal of Existing Roofing LS $5, •'' 3 Structural Repairs of Wood Trusses IS $2,745 4 Structural Connectors Work at Truss/Tie Beam LS $2,760• 5 New Standing Seam Metal Roofing System 1.5 $97,615 6 Exterior Stucco Finish and Paint LS $1,805 7 Lightning Protection System LS $6,785] 8 P&P Bond LS $2,345 Sub-Total Cost $127,455 Owner Allowance LS $20,000 Total Base Bld $147,455 UNIT PRICE 1 Remove and replace existing roof sheathing with new $95.00 SHEET roof sheathing-per sheet(4'x8'sheet) UNIT PRICE 2 Furnish and Install HGAM1OKT Anchor complete-as $15.00 EA indicated on S1.0-Connector Schedule-per each UNIT PRICE 3 Furnish and Install Mark 2 VGT Anchor complete as $25.00 EA indicated on 51.0-Connector Schedule-per each EXHIBIT A-2: CONTRACTOR'S BID SUBMITTAL FORMS AND ADDENDUM (FOLLOWING THIS PAGE) 9 Construction Services Agreement:Revised 072118 Page I of! Email: jimflanaganaoolliergov.net 1CT Telephone: (239)252-8946 • 10' r?PeZ ADDENDUM#1 Memorandum Date: April 18, 2019 From: Jim Flanagan, Procurement Strategist To: Interested Parties Subject: Addendum#1 — 19-7589 NCWRF Operations Building New Roof This addendum has been issued for the following items identifying changes, deletions, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike-through. • Attached: 19-7589—Addendum#1 -Technical Bulletin—Aluminum Bending > Attached: 19-7589—Addendum#1 -Pre-bid Meeting Minutes and Sign-in sheet Tz. The Bid Question period has closed as of April 16 close of business.All Bid Questions have been responded to on BidSync.All Bid Questions and Answers are hereby incorporated into the bid. Please acknowledge receipt of this Addendum with your bid proposal. Signature 6(..c Bidder J If you require ,Idditional information,please post a question on the Online Bidding site or contact me using the above contact information. eP FORM 1-BID RESPONSE FORM BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY,FLORIDA NCWRF Operations Building New Roof BID NO.19-7589 Full.Name of Bidder CFS Roe ring,Sen i.t s,.,l_l ` Main Business Address 12120 Amedieus Lane Fort Mey.s,FL 3'19.97 Place of Business Same Telephone No. (239)561-2600 Fax No. $208-3530 SContractor's License# CCCi 3h"w State of Florida Certificate of Authority Document Number Federal Tax Identification Number 27-1044026 DUNS# 962610049 CCR# Cage Code To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY,FLO' IDA (h ',: ' called the Owner) The un• r„;.,as Bidder declares that the only person or .'es interested in this Bid as principals are those named herein,that this Bid is submitted without collusion with any other person, firm or corporation;that it carefully examined the location of the proposed Work,the •.osed form of Agreement .,• all other Contract Documents and Bonds,and the Contract Drawings and Specifications. Bidder proposes, and f , -s if this Bid is accepted, Bidder will execute the A •• $t included in the Bidding Documents,to provide all necessary machinery,tools,apparatus and other means of construction, including utility and trans.• •tion services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth,furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract,and to do all other ,'. required of the Contractor by the Contract Documents,and "•.' it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points,and in the case where further decimal points are inadvertently provided,rounding to two decimal points will be conducted by Procurement Services Division staff. FORM 2.CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT • NCWRF Operations Building New Roof Bid No.19-7589 Name P=1.onnel CFS Roofing Services Julian Ferrer—Sr.Estimator(239)565-7806 12120 Amedicus Lane,Fort Myers,FL 33907 (239)561 -2600 Construction Superintendent Aaron Manuel(239)246-5541 Project NC• er David Bezendi—Sr.Project Manager(239)848.9991 FORM 3-MATERIAL MANUFACITRERS --I ____ THIS FORM MUST BE CO I'LETED OR BID SHALL BE DEEMED NON-IRESPONSEVE All Bidders shall coi by signature that they will provide the manufacturers and materials outlined in this Bid specifications,incl. #*#• compliance with Florida Statute 25520 to provide lumber,timber and other forest # 41 cts produced and manufactured in the State of Florida as long as the price,fitness and quelity are equal. Exceptions(when equals are acceptable) may be requested by compl ;#t the Me • ": Manufacturer Exception List below. If an exception for a manufacturer and/or material is proposed and listed below and is not approved by Engineer/Project Man:ter,Bi*,, shall furnish the manufacturer named in the specifi ;e'en.Acceptance of this form does not constitute ace-#e• cc of material proposed on this list. Complete and 5li. section A OR B. Section A(Acceptance of all manufactures and materials in Bid specifications) On behalf of my firms I confirm that we will use all manufacturers and materials as specifically outlined in the Bid specifications. Company: CFS RDelleg SeTvices,1-1,C Signature: Date: .04.05/2019 Section B(Exception requested to Bid specifications manufacturers and materials) EXCEPTION MATERIAL EXCEPTION MANUFACTURER 1. . . 2. - _ 3. N/A N/A 4. S. Please insert additional pages as necessary. Company: _C* ine. vtces.LLC - It' to Date 94125/20l9 0 FORM 4-LIST OF MAJOR SUBCONTRACTORS • '11:118 LIST MUST BE COMPLETED OR BID MAY BE DEEMED NON-RE ' I NSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories anti,... in the requirements of the Bid specifications. The undersigned acknowledges its responsibility for ens i'i 1 that the Subcontractors for the major categories listed herein are"qualified"(as defined in Ordinance 2017-08 and Section 15 of Instructions to Bidders)and meet all legal requirements applicable to and necessitated by the Contract Documents,including,but not limited to proper licenses, certifications, registrations and insurance cov ;le. The Owner reserves the right to disqualify any Bidder who includes non-compli: ii or non-qualified Subcontractors in its bid o i...Further,the Owner may direct the Successful Bidder to remove/replace any Subcontractor,at no additional cost to Owner,which is found to be non-compliant with this requirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents,the Successful Bidder shall identify all Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified :: noted above. Major Category of Work Subcontractor and Address 1. Electrical N/A 2. Mechanical N/A 3. Plumb:i Q. N/A 4. She Work N/A 5. Identify other subcontractors Lightning Protection Systems,Inc. that represent more than 10% 3818 Exchange Ave. 1 of price or that affect the Naples,FL 34104 critical path of the schedule ...... , Company: _AL! ' oMill or _ Otl I / Signature: _ Date: 04/25/2019 411) FORM -STATEMENT OF E i I NCR OF BIDDER The Bidder is required to state below what work of similar n "tude completed within the last five(5) y- - is a judge of its experience, skill and business standing and of its ability to conduct the work as completely and as rapidly as required under the terms of the Agreement, 1. Kalea Bay Condo,Phase I Kalea Bay Condo Association (project name) (project owner) Naples,FL 13960 Old Coast Rd,Naples FL 34110 (project location) (Owner's address) 21 Story New Construction.Combination Roof Manhattan Construction General Contractor (project description) (Owner's contact person) (title) 11/15/2017 (239)643-6000 $ 1.371,118.00 (project start/completion dates) (contract value) (phone) (email) 2. Bell Tower Shopping Center Bell Tower Shops,LLC (project name) (project owner) Fort Myers,FL Fort Myers,FL (project location) (Owner's address) Re-Roof Commercial Complex Jeff Spady Contractor Rep. (p description) (Owner's contact person) (title) 06/2019 (919)616-4715 jefl5thwallbdc.com $ 1.123.257.00 (project start/completion dates) (contract value) (phone) (email) 3. Magnolia Falls Magnolia Falls,Inc. (project name) (project owner) Naples,FL Naples,FL (profeet location) (Owner's address) 38 Condo Buildings—Tile ReRoof Velocity Engineering Services,LLC (project description) (Owner's contact person) (title) 06/2019 (239)689-1474 cingram@velocityengineering.com $ 250 900.00 (project start/completion dates) (contract value) (Phone) (email) RMS STATEMENT OF EXPERIENCE OF BIDDER 4. Walden Center Office Complex Walden Center (project name) (project owner) Bonita Springs,FL (project location) (Owner's address) Commercial Office Complex—Tile Reroof Ed Clarke CRE Property Manager (project description) (Owner's contact person) (title) 10/10/2018 edward.clarke@creconsultants.com ___... $534.914.00 ,rt 1239l 481 -3800 _ (project completion date) (contract value) (phone) (email) _.._..._ 5. Bella Casa Luxury Condo Bella case Luxury Condominium Assoc' ;on (project name) (project owner) Fort Myers,FL Fort Myers,FL (project location) (Owner's address) Multi Building Tile Reroof Cindy Stratton Prop. 4, ger Rep. (project description) (Owner's contact person) (title) 03/20/2019 (239)466—3716 cstratton@csmeollc.com $892.875.00 (project completion date) (contract value) (phone) . ... ._._ _._....... ,(email) 6. Partridge Point Condominium Partridge Point Condo Association (project name) (project owner) Naples,FL Naples,FL (project location) (Owner's address) 38 Buil.;•:_—Tile Reroof Danny Stokes Sr.Roof .t (project description) (Owner's contact person) (title) 10/2019 (954)275-8268 dannye 4ofcons t.com .., $.1,4110000 (project completion date) (contract value) (phone) (email) Company: ; " S. ' LLC Sia Date: 04/25/2019__ CA0 FORM 6-TRENCH SAFETY ACI Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are co n for complying with the Florida Trench Safety Act(90-96,Laws of Florida)effective October 1,1990.The further identifies the cost to be stmunarized below: Trench Safety Units of Unit Unit Extended Cost Measure Measure (Ouantity) Cost (Description) fLF,SY) N/A N/A N/A N/A N/A I 2. 3. 4. 5. TOTAL $ O 00 Failure to complete the above may result in the Bid being declared non-responsive. Company: CF fl Signature: Date: 04/25/2019 ID) i{77R[►i 7 1W)1 OND ICNOXV A1;1.,M!N BY.TAA E MOOS,thea wn CFS Roofing Services. LLC and T �I _9nnati Insurance company aft* 044 ter p'clrttil� _..he w. nr. •• • (herein called the Buret-Y:1, a cotpg4^atipn, chartered and exl gender theJitW$of#te$tett of,{ fhia _with its principal n the:city of Cincinnati and .abthloti S fo ,do business in the State of Florida are held, snd firmly, bound unto. sitr _flier County..Florida . (hereinafter Called the tet), .in the: fedi 'and. just stun of Flv Percent of.the Amount Bid ,.t ilarr.{1� 59� )•gond end lawful.money ofte'Udhed gates': of Amenod,.to be pard 411O6 demand of the 083ai0t,to which payment well andtnly to be made,the Principal and the Swet bind themselves,their heirs,and executors,achninistraters,.wid assign%jointly and severally and fafmly by Mesa,presents. Wheless,.the Principal is about td ettbciit;or has submitted.to The Owner,a Bid for furnishing all labor;materials,equipment and inegentalellerAlleary to furnish,Install,ad Rally complete the Work:otr thel?roject known 433 Bid No.14:.T 19CWIt 'Operations BelidlggNSWAoof., NOW,TatuvOMtf the Owner,hail eptthe B'id*f the'PRINCIPAL and the.PA N.CIPAT..shall enter into the;irequ ed Wit witb,the.thstiOr jot within ten•days afterthe date.tf `p=writ en Notice of Award:In aicaordafine with the:.terma of sueh Bids d$ivts duct bond or •Ld In an among of 100%the total.COnti'at;t_Aftlpunt as specified ht the ftt'dding Documents or.C,ontt'ect r ocu6Cuta With and sufftelentlunStyfor the faidtful.patruteuce Otte Agreement end forte porn*Iseyment of labor,tnabglebt tend:auppJJ.es furnished in .• ecegdon thereof or;in the•.ai!ertCttfthe.fbilure of the PRIT!4GIPAI.to eator=Into such Agreement Va"to give StElt bond or bonds,end delay r to Owner the required aettlflaatea of insurance,:if file l'R;INCUFA[.shall pay to the 0BUG 'the atm Of $ 5% t Cteho've as,llq tIdated : a�� Ses,'and not.as s penalty,as providedin the 3idditig:Doattmanta,then Ma obligation Shall be"twill •.vt'titi,.othbrsvisa bo remain ln,fitll forte end effect. IN TESTIMONY'Tlie sof the Principal end Sutety'have caused these'presents to be duly sighed and sealed this 25th day of April . 019 . CF Roof!a•, rvices.LLC J Principal }liY 1 • . i)F v.I Ceaal /eel).°. T (Seal) The.Cincinnati insur rice Garman,/ Satre O a _ Kevin P. �oltovlic ,Attorney-in-Fact find FL Licensed ResldentAgent Countersigned '' Appointed ProduCing Agent for Nielson.Wojtowlcz.'Neu&Associates 1000 Central Avenue, Suite 200, St. Petersburg,FL 33705 Upon uodfleationthat its:Old hes been.awarded,the Successful Bidder will execute the Agreettcent form attached to the.Bidding. Documents within.ten 1;•10 calendar clays and deliver the Surety ord or Bonds and th irate Certificates:as requlretlblethc Cont Docu ments.. he bid seetirity•atta hed Is tit becometha propel`of.the Owner IntheeVOntthe errant,Insurance CtrtifIaate+t and Bonds are not exec wain and-del)vered:to(honer'syiiMn::the time above set forth,as liquidated datneges,for the dbleyind:adfitionel expenso to the Otiiuer It'being:recognize fir }amyurs:tittie le of the essence,:O*rter Molal:sit r financiallose Otte$�iasfii1 Bidder faila�to,ezecute del perto Owner the recqutt Agr'eemen1 insurance Cett:'"flctee5.and.Bends withiwthe re4uired:tbne:petiod. In the event Ofesh'filllire::Thetotal amount oft ner'e demages,,will be difflallt,Ifnet thipossible,'todefinitei-sstdtletivand.quantify, It betel*,agreed thatit:ia appropf Ste,end flit 'that.Owner receive I litdated damages from the SucceSaful Bid*it intim event it fails to itte,ttge end deliver.the Agesentethi ligatrant0 Certificates,endb#14s,as required hereunder.the Stictiesajbl Bidder`hareby expresaly'°waive;s and relinquishes any h$ht'wltiab it may have to seek to cbracte tize:the above noted itquidated tomes as s penalttyy, whfdlt'tia*mato. septesonts*Viand-reasonable estimate of OWners Waal damages at tliO'dma orbiddit 3:If the successful Bidder fait to elute end deliver theArteroont,Insurance Certificatea and Bondy in a timely thither, her, Uppn.receipt'of the:sited,andepenned agreement:and P rebase Order,the.undetaigfed ptopolies to commence Work:et the Site Within five(S)tatendar day's f1'om,the commencement dere sttptiiwted In the written NOtICCIONOpeed unless the Pioj e}t:l hire er,in wridng, 'subsequently ,notifies the Contractor of a modified,(later) commencement date:.'The undersigned 'father' .ate two substantially complete-rill work covered by this bid within rlhrety(90) 'aonsecutt.VG Calendar days, computed by stab•,*.g eommnbnceniefli'date and including thelest day of suchperiod,and folse fully completed tb'the point iof mal ac danance by the te rwithin Thirty (30) utive calendar days after Substantial Completion, computed by including the list day ol'spa period. THE CINCINNATI INSURANCE COMPANY Fairfield, Ohio POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS:That THE CiNCI`NATi INSURANCE COMPANY,a corporation organized under the laws of the State of Ohio. and having its principal office in the City of Fairfield,Ohio,does hereby constitute and appoint Charles J.Nielson;David R.Hoover;Kevin R WVoj owiez;Charles a Nielson;Daniel F.Oaks:Laura D.,Mosholder;Don Brarnlage;Emily Golecki; Jarrett Merlucci;Shawn A.Burton;Edward M,Clark;Jessica P.Reno;Ian A.Nipper;Joseph P.Nielson andlor Edwin Turner Collins,IV of Miami Lakes,Florida its true and lawful Attorney(s)-in-Fact to sign,execute,seal and deliver on its behalf as Surety,and as its act and deed,any and all bonds,policies,undertakings,or other like instruments,as follows: Any such obligations in the United States,up to Twenty Million and No1100 Dolalrs(S20,000,000.00). This appointment is made under and by authority of the following resolution passed by the Board of Directors of said Company at a meeting held in the principal office of the Company, a quorum being present and voting. on the 6'' day of December, 1958, which resolution is still in Affect: "RESOLVED. that the President or any Vice President be hereby authorized, and empowered to appoint Attorneys-In- Fact of the Company to execute any and all bonds, policies, undertakings, or other like instruments on behalf of the Corporation. and may authorize any officer or any such Attorney-in-Fact to affix the corporate seal: and may with or without cause modify or revoke any such appointment or authority.Arty such writings so executed by such Attorneys-in- Fact shall be binding upon the Company as if they had been duty executed and acknowledged by the regularly elected officers of the Company." This Power of Attorney is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 7'h day of December. 1973. "RESOLVED, that the signature of the President or a Vice President and the seal of the Company may be affixed by facsimile on any power of attorney granted.and the signature of the Secretary or Assistant Secretary and the seal of the Company may be affixed by facsimile to any certificate of any such power and any such power of certificate bearing such facsimile signature and seal shall be valid and binding on the Company.Any such power so executed and sealed and certified by certificate so executed and sealed shall, with respect to any bond or undertaking to which it is attached. continue to be valid and binding on the Company." TN WITNESS WHEREOF,THE CINCINNATI INSURANCE COMPANY has caused these presents to be scaled with its corporate seal, duly attested by its Vice President this IP day of March,2017, 4'"'" THE CINCINNATI INSURANCE COMPANY �*' a SEAL ' 5.. ' rtiL-xt"' A C.:-'�' =t�. °"'° %Ice President STATE OF OHIO ) ss: COUNTY OF BUTLER ) On this 8" day of March. 2017. before me can; the above-named Vice President of THE CINCiN-NATI INSURANCE COMPANY,to me personally known to be the officer described herein,and acknowledged that the seal affixed to the preceding instrument is the corporate seal of said Company and the corporate seal and the signature of the officer were duly affixed and subscribed to said instrument by the authority and direction of said corporation. vows way._ \ ,, rte,.-. 1 r ( I : a � 'y; MARK J.H':ILLER,Attorney at Law fid? NOTARY PUBLIC-STATE OF Onto ‘,6 A M, ,' riv.1' My commission has no expiration %;,P Ricif a 0,4 date.Section 147.03 O.R.C. I.the undersigned Secretary or Assistant Secretary of THE CINCINNATI INSURANCE COMPANY,hereby certify that the above is a true and correct copy of the Original Power of Attorney issued by said Company. and do hereby further certify that the said Power of Attorney is still in full force and effect GIVEN under my hand and seal of said Company at Fairfield. Ohio. this 7 day of f'lcle- 1. .. =mart A Secretary 1 SEAL 4 • onto BN-1005 (3'17) Slate of afre County of ./P�a ' .. , ' _.. beingfirst dull sworn on oath deposes and says t the Bidder the.above Bid is. la..a-.• as Indicatedand that,. statements herein made are nutde on if of such Bidder and this deponan is authplizedto make them. ai _ ,also deposes and saysthat it bas examined earehdly prepared ice` ld from the Bidding Domutimits, incl #tag the Conhehtd Specifications and has Checked the same in detail ore sub }d; e stare .4 a2`. herein e and canna (a) .;t ' 5.b C. The Bidder is a . .. . ; 'cat ori ized and existing •r the laws of the State of 1, which tes under the legal mun0 of and the full names of its officers follows: S _.. _. iteagtireT The ' 04,„ _ is aua ' a*to sign construction bids and contracts for the c any by action of its iial3 .. ,1,"`... i',:'.w. . ,:... ..... (b)Co.p 4. #•7 The Bi.•w is a co--._ .,ening consistingof individual «ri ;era whose dill names am as follows:' The eo-panneaship does business under the legal name o (c)Individual and if operating undera e name,The Bidden is individual whosename is g tratk e is Complete for information contained in(a).Coration.(b)Co-P - •'.or(c)Individual from.previous page. D1,1 __ ' ...Sere, e, A _. Legal Entity BY: Witness „ of Bi # 4t „7 Witness `;fSignature rig tide STATE OF Acs COUNTY OF The s. =Mg instrument was acknowledged before me this day of , by ori, on behalf of the ccs ration He/she is personally knownto me or has produced — Identification and did(did not)take an oath. My Commission area: / .c(S No `) H ,. • al , nted) (A ' rr: u Notary Public,State of . . ,� 5 c t,..1 FORM$-INSURANCE AND BONDING REQUIREMENTS The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project,if required,to the full insurable value of the scope of work. The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design Consultant, Subcontractors,agents . employees of each and all of them,all . gas covered by property insurance provided herein,except such rights as they may have to the proceeds of such insurance. The Vendor and County shall,where appropriate,require similar waivers of subrogation from the County's separate Vendors,Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify"For any and all work performed on behalf of Collier County",or,the specific solicitation number and title. The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County,Florida,as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners,OR,Board of County Commissioners in Collier County,OR Collier County Government,OR Collier County.The Certificates of Insurance must state the Contract Number, or Project Number,or specific Project description,or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services I • cc(ISO)forms and endorsements or their equivalents. If Vendor has any self-insured retentions or deductibles under any of the below listed minimum required coverage,Vendor must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be Vendor's sole responsibility. Coveragefs)shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation1 whichever is longer. The Vendor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non-renewal on the part of the insurance carrier or the Vendor. The Vendor shall also notify the County,in a like manner,within twenty-four(24)hours after receipt,of any notices of expiration,cancellation,non-renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice.In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder,Vendor shall immediately take steps to have the a: i gate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverage()required herein,the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage and charge the Vendor for such coverage(j)purchased. If Vendor fails to reimburse the County for such costs within thirty(30)days after demand,the County has the right to offset these costs from any amount due Vendor under this Agreement or any other agreement between the County and Vendor.The County shall be under no obli 9,;on to purchase such insurance,nor shall it be responsible for the coy , efs)purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverageb),shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work,the Vendor shall furnish to the County renewal or replacement Certificate(s)of Insurance not later than ten(10)calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s)shall be considered justification for the County to terminate any and all contracts. (...2.o ler KritY FORM 9-CONFLICT OF INTEREST AFFIDAVIT The Vendor certifies that,to the best of its knowledge and belief;the past and current work on any Collier County project affiliated with this solicitation does not pose an organizational conflict as described by one of the three categories below: Biased ground rules—The firm has not set the"ground rules"for affiliated past or current Collier County project identified above(e.g., writing a procurement's statement of work, specifications, or performing systems engineering and technical direction for the procurement)which appears to skew the competition in favor of my firm. Impaired objectivity—The firm has not performed work on an : past or current Collier County project identified above to evaluate proposals/past performance of itself or a competitor,which calls into question the contractor's ability to render impartial advice to the government Unequal access to information—The firm has not had access to nonpublic information as part of its performance of a Collier County project identified above which may have provided the contractor(or an affiliate)with an unfair competitive advantage in current or future solicitations and contracts. In .' tion to this signed affidavit,the contractor/vendor must provide the following: 1. All documents produced as a result of the work completed in the past or currently being worked on for the above-mentioned project;and, 2. Indicate if the information produced was obtained as a matter of public record(in the"sunshine")or through non-public(not in the"sunshine")convers (s),meeting(s),document(s)and/or other means. Failure to disclose all material or having an organizational conflict in one or more of the three c.i-gories above be identified,may result in the disqualification for future solid :, ons affiliated with the above referenced project(s). By the si attire below,the firm(employees,officers. or agents)certifies,and hereby discloses,that,to the best of their knowledge and belief,all relevant facts concerning past,present,or currently planned interest or activity(financial,contractual,or::.•izational, or otherwise)which relates to the project identified above has been fully disclosed and does not pose an ' ' ;onal conflict. Firm: R -erdia.LLC Signature and Date: IX/25/2o 19 Print Name: David Crowther Title of Signatory: President :Swim Ducart;:, Psraaviwit wow. FORM 10-VENDOR DECLARATION STATEMENT BOARD OF cowry COMMISSIONERS Collier County Government Complex Naples,Florida 34112 Dear Commissioners: The undersigned, Vendor declares that this response is se without connection or arrangement with any other person and this proposal is in every respect fair and made in good faith,without collusion or fraud. The Vendor agrees,if this solicitation submittal is accepted,to execute a Collier County document for the purpose of establishing a formal contractual relationship between the firm and Collier County,for the . .nnance of all requirements to which the solicitation pertains. The Vendor states that the submitted is based upon the documents listed by the above referenced Solicitation. Further,the vendor agrees that if awarded a contract for these goods and/or services,the vendor will not be eligible to compete,submit a pro i1,be awarded,or perform as a sub-vendor for any future associated with work that Is a result of this awarded contract IN WITNESS WHEREOF,WE have hereunto subscribed our names on this 25 day of April ,20 19 in the Cotmty of Collier in the S.., of Florida Firm's Legal Name: CFS Roofing Services,LLC Ad., —s: 12120 Amedicus Lane City,State,Zip Code: Fort Myers,FL 33907 Florida Certificate of Authority Document Number Federal Tax ;7.-1044026 Identification Number *CCR#or CAGE Code *Only if Grant Funded Telephone: (239)561 -2600 Signature by: David Crowther (Typed aid written) Title: President Additional Contact Information Send payments to: CFS Roofing Services,LLC (required if different from Company name used as payee above) Contact name: Dawn Kerton Title: Account Receivable Address: 12120 Amedicus Lane City,State,ZIP Fort 114,ers Fl 33907 Telephone: (239)561 -2600 Email: D.Karton@CFSRoofing.com Office servicing Collier County to place orders (required if different from above) Contact name: Title: Address: City,State,ZIP Telephone: Email: Secondary Contact for this David Berendt Solicitation: Email: D.Bertatcit tpCFSRoofertg.com Phone: (239)848-9991 Cc)itter CatilIttlY Atitntrild •,* Vricolook:Vvistar, FO' 11-IMMIGRATION AFFIDAVIT CERTIFICATION This Affidavit is required and should be signed,notarized by an authorized principal of the firm and submitted with formal solicitation submittals. Further,Vendors are required to enroll in the E-Verify pro L. " and provide acceptable evidence of their enrollment,at the time of the submission of the Vendor's proposal. Acceptable evidence consists of a copy of the properly completed&Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Und, 'ding for the company. Failure to include this Affidavit and acceptable evidence of enrollment in the E-VerifY nroaram may deem the Vendor's proposal as non- responsive. Collier County will not intentionally award County contracts to any Vendor who knowingly employs unauthorized alien workers, constituting a violation of the loyment provision contained in 8 U.S.C. Section 1324 a(e) Section 274A(e)of the ..u zi Won and Nationality Act("INA"). Collier County may consider the employment by any Vendor of unauthorized aliens a violation of Section 274A(e)of the INA. Such Violation by the recipient of the Employment Provisions contained in Section 274A(e)of the INA shall be grounds for unilateral termination of the contract by Collier County. Vendor attests that they are fully compliant with all applicable immi on laws(specifically to the 1986 Immigration Act and subsequent Amendment(s)) d agrees to comply with the provisions of the Memorandum of Understanding with E-Verify and to provide proof of enrollment in The Employment Eligibility Verification System(I3-Verify),operated by the Dc. . ent of Homeland Security in partnership with the Social Security Administration at the time of submission of the Vendor's proposal. Company Name CFS Root:mi,„5si:qce ,„LI t Print N: e David holt Title President \ S' ; \ Date 04/25/2019 State of Florida County of LEE The signee of these Affidavit : tees,as evidenced by the sworn affidavit required herein,the truth and accuracy of this affidavit to interrogatories hereinafter made. Commission No.: CAO CA',,'OW Ceti FO 12-VENDORS W-9 Request for Taxpayer Identification Number and Certification In accordance with the Internal Revenue Service regulations,Collier County is required to collect the following information for tax reporting purposes from individuals and companies who do business with the County(including social security numbers if used by the individual or company for tax reporting purposes). Florida Statute 119.071(3)requires the county notify you in writing of the reason for collecting this information,which will be used for no other purpose than herein stated. Please complete all information that applies to your business and return with your quote or proposal. 1. General Information(provide all information) Taxpayer Name v •gib %von.. _ . a- c----- (as shown on income tax return) ).._. Business .r le, n p, ,. ) IAddress a i. J a r dine City ". � State �" ... Zip. _ .... ... I Telephone Z' 1"' S GO l-2/4006O6 Email Order Information(Must be filled out) Remit I Payment Information�� (Must be fitled out) Address i2A2.0 Awregzi1 ` Address 1212 C) t C.ds rye i City '4'state a- Zip S _.._..dicity Pt..tYllitiS State Pta• Zip 319.0 7 Email last) CCS['ttY"�.Corn Email V. e•exAit*Sl@ CcSrOc ' rY7 1 V 2. Company Status(check only one) -aa(Sole Prolm`etor N ._Corporation _; 'art:ers ,ip.. r do«,.a, be/f 4- Tax Exempt(F income tax-exempt entityty(ompa ny 1.�m�te��I.ialali under Internal Revenue Service guidelines IRC Enter the tax classification 501(c)3) (D=Disregarded Entity,C=Corporation,P=Partnership)•. 3. Taxpayer Identification Number(for tax reporting purposes only) Federal Tax Identification Number 104, ,,,,�,__ ... k Vendors who da have a TIN will be rewired to proNide a social security.number prior to an award 4. Sign and Date Form:Certification: Under i °nalties,..4 ie$r rah that the itsiormation shown on this corm is correct to no knowledge , Si,�-,naso' , ' , 417ji l _. , Ptest• lb(vi- to Title 0 „„. FORM 13-BIDDERS CHECKLIST IORTANT: Please read carefully,si in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the ne,ces.: action is completed: 1. The Bid has been 2. The Bid prices offered have been reviewed. 3. The price extensions and totals have been checked. 4. Bid Schedule : been completed and attached. 5. Any required drawings,descriptive literature,etc.have been included. 6. Any delivery information required is included. 7. The following on-line . a documents have been reviewed in Bidsync: 1. Construction bid instructions form 2. Construction services agreement 3. Purchase order terms and conditions 8. All of the following bid forms have been completed and si:ned: 1. Bid Form(Form 1) 10. Vendor Declaration Statement(Form 10) 2. Contractors Key Personnel(Form 2) 11. Immigration Law A .. vit Certification 3. Material Manufacturers(Form 3) (Form 11) 4. List of Major Subcontractors(Form 4) 12, Vendor Substitute W-9(Form 12) 5. Statement of Experience(Form 5) 13. Bidders Checklist(Form 13-this form) 6. Trench Safety Act(Form 6) 14. Business tax Receipt(Collier County 7. Bid Bond Form(Form 7) Businesses Only) 8. Insurance and Bonding Requirements(Form 8) 15. S' ed Grants Provisions Package(if 9. Conflict of Interest Affidavit(Form 9) applicable 9. Copies of required information have been attached 1. Company's E-Ve:rify profile page or memorandum of understanding 2. Certificate of Authority to Conduct Business in State of Florida 3. Any required professional licenses-valid and current (ie:General Contractors license,Underground Utility and Excav:u.'on,Builders, Trade Contractors,etc.,as applicable,requested and/or required.) 10. If required,the amount of Bid bond has been checked,and the Bid bond or cashier's check has been submitted. 11. Any addenda have been signed and acknowledgement form hed and included. 12. The Bid will be uploaded in time to be received no later than the specified .. . e and time,otherwise the Bid cannot be considered. CFS Roo": Services,LLC Bidder Name Davi ON ident 0425/2019 fir SI, 'AI I :* jt Date I I I *, • O c ce w J 0 U.] Ce pU-1 WLE ce �- w Q w W vv) J 0 o a Q m Z ° � le , 0 N 2 z Z ( Q I 0 o cu 141 z w sN O V) V1 Q U i c H IO Z ' o —1O Oc" Q tr) � > J W • M M >• 'CU W w M J Um UaUi F � ca /1 V O w < M 0 ' N :0 c w VVJ U 'J J j ' D '6 -C „..0..1 Li. F--' w d- W o 0 o O Z O' _ T CO LUN ill o a) Q ce= LU �1. z 2 ce "El< = in 0 0 c Z +, c Z O C °' 1 QW v = O 8n - OcDC w 0 zZ LL_ zH u O ; v) z O oF- O cn V x -, a .E m V U z x > = LL n O LU >, .N 0 rz in o i— I".' O > Q a; O c W Z a u O w -: o V 0 o Q .- N CL LE u W i- 0 lug p 3g J i f),1 Qypartmenl of State / Divisionof Corporations / Search Records / Detail By Document Number / Detail by Entity Name Florida Limited Liability Company CFS ROOFING SERVICES, LLC Filing Information Document Number L09000094721 FEI/EIN Number 27-1044026 Date Filed 10/01/2009 State FL Status ACTIVE Last Event LC NAME CHANGE Event Date Filed 09/13/2012 Event Effective Date NONE Principe Address 12120 AMEDICUS LANE FORT MYERS, FL 33907 Changed: 02/01/2011 Mailing Address 12120 AMEDICUS LANE FORT MYERS, FL 33907 Changed: 02/01/2011 Registered Agent Name&Address ALOIA, FRANK J., Jr. 2254 FIRST STREET FORT MYERS, FL 33901 Name Changed: 04/06/2016 Address Changed: 04/06/2016 Authorized Person(s)Detail Name&Address Title MGRM CROWTHER HOLDINGS, INC. 12120 AMEDICUS LANE FORT MYERS, FL 33907 Annual Reports Report Year Filed Date 2017 04/04/2017 2018 01/17/2018 2019 02/15/2019 Document Images 02/15/2019—ANNUAL REPORT View image in PDF format 01/17/2018—ANNUAL REPORT View image in PDF format 04/04/2017—ANNUAL REPORT View image in PDF format • 04/05/2015--ANNUAL REPORT View image in PDF format 04/22/2015—.ANNUAL REPORT View image in PDF format 01/24/2014--ANNUAL REPORT View image in PDF format 03/11/2013--ANNUAL REPORT View image in PDF format 00/13/2012--LC Name Change View image in PDF format 01/05/2012—ANNUAL REPORT View image in PDF format 04/06/2011--ANNUAL REPORT View image in PDF format • 02/15/2011--LC Name Change View image in PDF format 02101/2011--LC Amendment View image in PDF format 04/27/2010--ANNUAL REPORT View image in PDF format 02/01/2010--LC Amendment View image in PDF format 10/01/2009—Florida Limited Liability, View image in PDF format C�v ...,,,,,,, C im 7:: — en _ ..,. :` yet Company ID Number: 407348 THE E VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY • The parties to this agreement are the Department of Homeland Security(DHS)and the CFS Roofing Services, LLC(Employer). The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E-Verify. E-Verify Is a program that electronically confirms an employee's eligibility to work In the United States after completion of Form 1-9, Employment Eligibility Verification(Form 1-9).This Memorandum of Understanding (MOU)explains certain features of the E-Verify program and describes specific responsibilities of the Employer,the Social Security Administration(SSA),and DHS. Authority for the E-Verify program is found In Title IV, Subtitle A, of the Illegal immigration Reform and Immigrant Responsibility Act of 1996(IIRIRA), Pub. L. 104-208, 110 Stat. 3009, as amended(8 U.S.C. § 1324a note).The Federal Acquisition Regulation(FAR)Subpart 22.18, 'Employment Eligibility Verification'and Executive Order 12989,as amended, provide authority for Federal contractors and subcontractors(Federal contractor)to use E-Verify to verify the employment eligibility of certain employees working on Federal contracts. ARTICLE It RESPONSIBILITIES A.RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the following notices supplied by OHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system: a. Notice of E-Verify Participation b. Notice of Right to Work 2. The Employer agrees to provide to the SSA and OHS the names,titles,addresses, and telephone numbers of the Employer representatives to be contacted about E-Verify. The Employer also agrees to keep such information current by providing updated information to SSA and OHS whenever the representatives'contact information changes. 3. The Employer agrees to grant E-Verify access only to current employees who need E-Verify access. Employers must promptly terminate an employee's E Verify access if the employer Is separated from the company or no longer needs access to E-Verify. Page 1 of 17 E•Verify MOU for Employers l Revision Date 06/01/13 E-Verily ;,,, Company ID Number. 407348 4. The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual. 5. The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that Individual creates any cases. a. The Employer agrees that ail Employer representatives will take the refresher tutorials when prompted by E-Verify in order to continue using E-Verify. Failure to complete a refresher tutorial will prevent the Employer Representative from continued use of E-Vertfy. 6. The Employer agrees to comply with current Form 1-9 procedures, with two exceptions: a. If an employee presents a"List B"identity document, the Employer agrees to only accept"List B"documents that contain a photo. (List B documents Identified in 8 C.F.R. §274a.2(b)(1)(B))can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons,the Employer should contact E-Verify at 888-464-4218. b. if an employee presents a DHS Form 1-551 (Permanent Resident Card), Form 1-786 (Employment Authorization Document), or U.S. Passport or Passport Card to complete Form 1-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employee's Form 1-9.The Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest. DHS may In the future designate other documents that activate the photo screening tool. Note:Subject only to the exceptions noted previously In this paragraph, employees still retain the right to present any List A, or List B and List C, document(s)to complete the Form 1-9. 7. The Employer agrees to record the case verification number on the employee's Form 1-9 or to print the screen containing the case verification number and attach it to the employee's Form 1-9. 8. The Employer agrees that, although it participates in E-Verify,the Employer has a responsibility to complete, retain,and make available for inspection Forms 1-9 that relate to its employees,or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 2748 of the INA with respect to Form 1-9 procedures. a. The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti-discrimination provision of the INA: (1)List B identity documents must have photos, as described in paragraph 6 above;(2)When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(a)(1)(A)of the immigration and Nationality Act(INA)with respect to the hiring of that employee;(3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penalty between$550 and$1,100 for each failure to notify DHS of continued employment following a final nonconfimiation; (4) If the Employer continues to employ an employee after receiving a final nonconfirmation, then the Employer is subject to a rebuttable presumption that it has knowingly Page 2 of 17 E-Yertfy MOU for Employers I Revision Data 08/01/13 S . %kJ. „,'' eri y t X Company ID Numbor: 407348 employed an unauthorized alien in violation of section 274A(a)(1)(A);and(5)no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Vertfy. b. DHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits,to ensure proper use of E-Verlfy. 9. The Employer is strictly prohibited from creating an E-Verlfy case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed. The Employer agrees to create an E-Verify case for new employees within three Employer business days after each employee has been hired(after both Sections 1 and 2 of Form 1-9 have been completed),and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual. if E-Verify is temporarily unavailable, the three-day time period will be extended until It is again operational in order to accommodate the Employer's attempting, in good faith,to make inquiries during the period of unavailability. 10. The Employer agrees not to use E-Verify for pre-employment screening of Job applicants, In support of any unlawful employment practice, or for any other use that this MOU or the E-Verify User Manual does not authorize. 11.The Employer must use E-Verify for all new employees. The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU. Employers who are Federal contractors may qualify for exceptions to this requirement as described In Article 11.8 of this MOU. 12. The Employer agrees to follow appropriate procedures(see Article Ill below)regarding tentative nonconfirmations. The Employer must promptly notify employees In private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral Instructions to employees and Instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding,and not take adverse action against employees if they choose to contest the finding,while their case is still pending. Further,when employees contest a tentative nonconflrmation based upon a photo mismatch,the Employer must take additional steps (see Article 11I.B. below)to contact DHS with information necessary to resolve the challenge. 13. The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DHS is processing the verification request unless the Employer obtains knowledge(as defined in 8 C.F.R.§274a.1(1))that the employee is not work authorized.The Employer understands that an initial Inability of the SSA or DHS automated verification system to verify work authorization, a tentative nonconfirmatlon, a case in continuance (indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch,does not establish, and should not be interpreted as, evidence that the employee is not work authorized. In any of such cases,the employee must be provided a full and fair opportunity to contest the finding, and if he or she does so,the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status Pope 3 of 17 E-Verify MOU for Employers l Revision Date 06/01/13 'AA' ',a t., ' '''. ill Company ID Number. 407348 (including denying, reducing, or extending work hours, delaying or preventing training,requiring an employee to work In poorer conditions,withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmatlon has been issued. if the employee does not choose to contest a tentative nonconflrmation or a photo mismatch or If a secondary verification is completed and a final nonconflrmation is issued,then the Employer can find the employee is not work authorized and terminate the employee's employment. Employers or employees with questions about a final nonconflrmation may call E-Verify at 1-888-484- 4218(customer service)or 1-888-897-7781 (worker hotline). 14. The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 274B of the INA as applicable by not discriminating unlawfully against any individual in hiring,firing, employment eligibility verification,or recruitment or referral practices because of his or her national origin or citizenship status,or by committing discriminatory documentary practices.The Employer understands that such illegal practices can include selective verification or use of E-Verify except as provided in part D below,or discharging or refusing to hire employees because they appear or sound "foreign"or have received tentative nonconfirmations.The Employer further understands that any violation of the immigration-related unfair employment practices provisions in section 2748 of the INA could subject the Employer to civil penalties, back pay awards,and other sanctions,and violations of Title VII could subject the Employer to back pay awards,compensatory and punitive damages. Violations of either section 2748 of the INA or Title VII may also lead to the termination of its participation in E-Verify. If the Employer has any questions relating to the anti-discrimination provision, It should contact OSC at 1-800-255-8155 or 1-800-237-2515(TDD). 15. The Employer agrees that It will use the information it receives from E-Verify only to confirm the employment eligibility of employees as authorized by this MOU.The Employer agrees that it will safeguard this information, and means of access to It(such as PINS and passwords),to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU,except for such dissemination as may be authorized in advance by SSA or DHS for legitimate purposes. 18. The Employer agrees to notify DHS immediately in the event of a breach of personal information. Breaches are defined as loss of control or unauthorized access to E-Verify personal data. Ail suspected or confirmed breaches should be reported by calling 1-888-464-4218 or via email at E-Vertfvdhs.gov. Please use"Privacy Incident—Password" in the subject line of your email when sending a breath report to E-Verify. 17. The Employer acknowledges that the information It receives from SSA is governed by the Privacy Act(5 U.S.C.§552a(i)(1)and(3))and the Social Security Act(42 U.S.C. 1306(a)). Any person who obtains this Information under false pretenses or uses It for any purpose other than as provided for in this MOU may be subject to criminal penalties. 18. The Employer agrees to cooperate with OHS and SSA In their compliance monitoring and evaluation of E-Verify,which includes permitting OHS, SSA,their contractors and other agents, upon Page 4 of 17 E•Verfy MOU for Employers I Revision Date 06/01/13 CAO FT.. Company ID Number, 407348 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for Information relating to their participation in E-Verify. 19. The Employer shall not make any fat- or unauthorized claims or references about Its participation in E-Vertfy on its website, in advertising materials, or other media. The Employer shall not describe its services as federally-approved,federally-certified,or federally-recognized, or use language with a similar intent on its website or other materials provided to the public. Entering Into this MOU does not mean that E-Verify endorses or authorizes your E-Verify rvices and any claim to that effect is false. 20. The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS. 21. The Employer agrees that E-Vertfy trademarks and logos may be used only under license by DHS/USCiS (see M-795(Web))and,other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services, products, websites, or publications are sponsored by, endorsed by, licensed by, or affiliated with DHS, USCIS, or E-Verify. 22, The Employer understands that if It u- s E-Verify procedures for any purpose other than authorized by this MOU,the Employer may be subject to appropriate legal action and termination of its participation In E-Verify according to this MOU. B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1. If the Employer is a Federal contractor with the FAR E-Verify clause subject to the employment verification terms in Subpart 22.18 of the FAR, it will become familiar with and comply with the most current version of the E-Verify User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors. 2. In addition to the responsibilities of every employer outlined In this MOU, the Employer understands that if It is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR It must verify the employment eligibility of any'employee assigned to the contract" (as defined in FAR 22.1801). Once an employee has been verified through E-Vertfy by the Employer,the Employer may not create a ==cond case for the employee through E-Verify. a. An Employer that Is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and,within 90 days of enrollment, begin to verify employment eligibility of new hires using E-Verify. The Employer must verify those employees who are working in the United States, whether or not they are assigned to the contract. Once the Employer begins verifying new hires, such verification of new hires must be initiated within three business days after the hire date.Once enrolled in E-Vertfy as a Federal contractor,the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract,whichever date is later. Pape 5 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 S 111"1111 161 4"' stroW apt r',4 -VerilyA V ,til +nsi9a Company ID Number: 407348 b. Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States,whether or not assigned to the contract, within three business days after the date of hire. If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award,the Employer must,within 90 days of enrollment,begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States,whether or not assigned to the contract.Such verification of new hires must be initiated within three business days after the date of hire.An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract,whichever is later. c. Federal contractors that are Institutions of higher education(as defined at 20 U.S.C. 1001(a)), state or local governments,governments of Federally recognized Indian tribes,or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract Such Federal contractors may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986. Employers In this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later. d. Upon enrollment, Employers who ars Federal contractors may elect to verify employment eligibility of ail existing employees working in the United States who were hired after November 6, 1986, instead of verifying only those employees assigned to a covered Federal contract.After enrollment, Employers must elect to verify existing staff following DHS procedures and begin E-Verify verification of all existing employees within 180 days after the election. e. The Employer may use a previously completed Form 1-9 as the basis for creating an E-Verify case for an employee assigned to a contract as long as: i. That Form 1-9 Is complete(Including the SSN)and compiles with Article ii.A.6, ii. The employee's work authorization has not expired, and iii. The Employer has reviewed the Form 1-9 information either in person or in communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed(including, but not limited to, a lawful permanent resident alien having become a naturalized U.S.citizen). f. The Employer shall complete a new Form 1-9 consistent with Article I1.A.6 or update the previous Form 1-9 to provide the necessary information if: I. The Employer cannot determine that Form 1-9 compiles with Article II.A.6, ii. The employee's basis for work authorization as attested in Section 1 has expired or changed, or The Form 1-9 contains no SSN or Is otherwise incomplete. Note: if Section 1 of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies with Pape 8 of 17 E-Verify MOU for Employeis I Revision Date 06/01/13 --- ri. -,,, is srM Company ID Number. 407348 Article II.C.5, but reflects documentation(such as a U.S. passport or Form 1-551)that expired after completing Form 1-9, the Employer shall not require the production of additional documentation,or use the photo screening tool described in Article II.A.5, subject to any additional or superseding instructions that may be provided on this subject In the E-Verify User Manual. g. The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3. The Employer understands that If It is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract,and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements. C. RESPONSIBILITIES OF SSA 1. SSA agrees to allow DHS to compare data provided by the Employer against SSA's database. SSA sends DHS confirmation that the data sent either matches or does not match the information in SSA's database. 2. SSA agrees to safeguard the information the Employer provides through E-Verify procedures. SSA also agrees to limit access to such information, as is appropriate by law, to Individuals responsible for the verification of Social Security numbers or responsible for evaluation of E-Verify or such other persons or entities who may be authorized by SSA as governed by the Privacy Act(5 U.S.C. §552a), the Social Security Act(42 U.S.C. 1306(a)), and SSA regulations(20 CFR Part 401). 3. SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry. E-Verify provides the information to the Employer. 4. SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence. If the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA,SSA agrees to update SSA records, If appropriate, within the eight-day period unless SSA determines that more than eight days may be necessary. In such cases,SSA will provide additional instructions to the employee. if the employee does not visit SSA in the time allowed, E-Verify may provide a final nonconfirmation to the employer. Note: If an Employer experiences technical problems, or has a policy question, the employer should contact E-Verify at 1-888-464-4218. D.RESPONSIBILITIES OF DHS 1. OHS agrees to provide the Employer with selected data from DHS databases to enable the Employer to conduct,to the extent authorized by this MOU: a. Automated verification checks on alien employees by electronic means,and Page 7 of 17 E-Verify MOW for Employers I Revision Date 08101/18 Verily Company ID Number: 407348 b. Photo verification checks(when available)on employees. 2. DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. DHS agrees to provide the Employer names,titles, addresses, and telephone numbers of DHS representatives to be contacted during the E-Verify process. 3. OHS agrees to provide to the Employer with access to E-Verify training materials as well as an E-Vertfy User Manual that contain instructions on E-Verify policies, procedures, and requirements for both SSA and DHS, including restrictions on the use of E-Verify. 4. DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manual. Even without changes to E-Verity, DHS reserves the right to require employers to take mandatory refresher tutorials. 5. OHS agrees to provide to the Employer a notice,which Indicates the Employer's participation in E-Verify. DHS also agrees to provide to the Employer anti-discrimination notices issued by the Office of Special Counsel for Immigration-Related Unfair Employment Practices(OSC),CMI Rights Division, U.S. Department of Justice. 6. OHS agrees to issue each of the Employer's E-Verify users a unique user identification number and password that permits them to log In to E-Verify. 7. DHS agrees to safeguard the Information the Employer provides,and to limit access to such information to individuals responsible for the verification process,for evaluation of E-Verify,or to such other persons or entities as may be authorized by applicable law. Information will be used only to verify the accuracy of Social Security numbers and employment eligibility,to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements. 8. DHS agrees to provide a means of automated verification that provides(in conjunction with SSA verification procedures)confirmation or tentative nonconfirmation of employees'employment eligibility within three Federal Government work days of the initial inquiry. 9. OHS agrees to provide a means of secondary verification(including updating DHS records)for employees who contest DHS tentative nonconflrmatlons and photo mismatch tentative nonconfirmations.This provides final confirmation or nonconfirmation of the employees'employment eligibility within 10 Federal Government work days of the date of referral to OHS, unless OHS determines that more than 10 days may be necessary. In such oases, OHS will provide additional verification instructions. ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA 1. If the Employer receives a tentative nonconfirmation issued by SSA,the Employer must print the notice as directed by E-Verify. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify Peps 8 of 17 E-Verify MOU for Employers(Revision Deis 08101/13 €7‘;) r 1apt Ve 4LT Company ID Number: 407348 case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding,while their case Is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmatlon. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed by E-Verify. The Employer must record the case verification number, review the employee Information submitted to E-Verify to identify any errors,and find out whether the employee contests the tentative nonconfirmation.The Employer will transmit the Social Security number,or any other corrected employee information that SSA requests,to SSA for verification again If this review indicates a need to do so. 4. The Employer will instruct the employee to visit an SSA office within eight Federal Government work days. SSA will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 6. While waiting for case results,the Employer agrees to check the E-Verify system regularly for case updates. 6. The Employer agrees not to ask the employee to obtain a printout from the Social Security Administration number database(the Numident)or other written verification of the SSN from the SSA. B. REFERRAL TO DHS 1. If the Employer receives a tentative nonconfirmation issued by DHS,the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees.The Employer must allow employees to contest the finding,and not take adverse action against employees If they choose to contest the finding,while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. The Employer agrees to refer individuals to OHS only when the employee chooses to contest a tentative nonconfirmation. 4. If the employee contests a tentative nonconfirmatlon Issued by DHS,the Employer will Instruct the Page 9 0117 E-Ver fy LOU for Employers t Revision Date 06/01/43 y. ,..w.zt am 1 ....+ S 'aV7� eri ... Company ID Number: 407348 employee to contact DHS through its toll-free hotline(as found on the referral letter)within eight Federal Government work days. 5. If the Employer finds a photo mismatch,the Employer must provide the photo mismatch tentative nonconflrmation notice and follow the Instructions outlined in paragraph 1 of this section for tentative nonconfirmations,generally. 6. The Employer agrees that if an employee contests a tentative nonconfinnation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1-551, Form 1-766, U.S. Passport,or passport card to DHS for review by: a. Scanning and uploading the document, or b. Sending a photocopy of the document by express mail(furnished and paid for by the employer). 7. The Employer understands that if it cannot determine whether there Is a photo match/mismatch,the Employer must forward the employee's documentation to OHS as described in the preceding paragraph. The Employer agrees to resolve the case as specified by the DHS representative who will determine the photo match or mismatch. 8. DHS will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless It determines that more than 10 days Is necessary. 9. While waiting for case results,the Employer agrees to check the E-Verify system regularly for case updates. ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1. SSA and OHS will not charge the Employer for verification services performed under this MOU.The Employer is responsible for providing equipment needed to make inquiries.To access E-Verify,an Employer will need a personal computer with Internet access. ARTICLE V MODIFICATION AND TERMINATION A. MODIFICATION 1. This MOU Is effective upon the signature of ail parties and shall continue in effect for as long as the SSA and OHS operates the E-Verify program unless modified in writing by the mutual consent of all parties. 2. Any and all E-Verify system enhancements by DHS or SSA, Including but not limited to E-Verify checking against additional data sources and instituting new verification policies or procedures,will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes. Page 10 of 17 E-Verify MOU for Employers I Revision Dais 06101/13 EVerify . 40i."4 Company ID Number: 407348 B. TERMINATION 1. The Employer may terminate this MOU and its participation In E-Vertfy at any time upon 30 days prior written notice to the other parties. 2. Notwithstanding Article V, part A of this MOU, DHS may terminate this MOU, and thereby the Employer's participation in E-Verify,with or without notice at any time if deemed necessary because of the requirements of law or policy, or upon a determination by SSA or DHS that there has been a breach of system integrity or security by the Employer, or a failure on the part of the Employer to comply with established E-Verify procedures and/or legal requirements.The Employer understands that tf it is a Federal contractor,termination of this MOU by any party for any reason may negatively affect the performance of its contractual responsibilities. Similarly, the Employer understands that if It is in a state where E-Verify is mandatory,termination of this by any party MOU may negatively affect the Employer's business. 3. An Employer that is a Federal contractor may terminate this MOU when the Federal contract that requires its participation in E-Verify Is terminated or completed. In such cases,the Federal contractor must provide written notice to OHS. If an Employer that is a Federal contractor fails to provide such notice,then that Employer will remain an E-Verify participant,will remain bound by the terms of this MOU that apply to non-Federal contractor participants, and will be required to use the E-Verify procedures to verify the employment eligibility of all newly hired employees. 4.The Employer agrees that E-Verify is not liable for any losses,financial or otherwise, if the Employer is terminated from E-Verify. ARTICLE VI PARTIES A. Some or all SSA and DHS responsibilities under this MOU may be performed by contractor(s),and SSA and DHS may adjust verification responsibilities between each other as necessary. By separate agreement with OHS, SSA has agreed to perform its responsibilities as described in this MOU. B. Nothing in this MOU Is intended, or should be construed,to create any right or benefit,substantive or procedural, enforceable at law by any third party against the United States, its agencies, officers, or employees,or against the Employer, its agents, officers,or employees. C.The Employer may not assign, directly or indirectly,whether by operation of law, change of control or merger, all or any part of Its rights or obligations under this MOU without the prior written consent of DHS,which consent shall not be unreasonably withheld or delayed. Any attempt to sublicense,assign, or transfer any of the rights, duties,or obligations herein Is void. D.Each party shall be solely responsible for defending any claim or action against It arising out of or related to E-Verity or this MOU,whether civil or criminal,and for any liability wherefrom, including(but not limited to) any dispute between the Employer and any other person or entity regarding the applicability of Section 403(d)of IIRIRA to any action taken or allegedly taken by the Employer. E.The Employer understands that its participation in E Verify is not confidential information and may be disclosed as authorized or required by law and DHS or SSA policy, including but not limited to, Page 11 of 17 E-Verily MOO for Employers I Revision Date 08/01/13 CACI er Company ID Number: 407348 Congressional oversight, E-Verify publicity and media inquiries,determinations of compliance with Federal contractual requirements,and responses to inquiries under the Freedom of Information Act (FOIA). F. The Individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer and DHS respectively. The Employer understands that any Inaccurate statement, representation,data or other information provided to DHS may subject the Employer, Its subcontractors, Its employees, or Its representatives to: (1)prosecution for false statements pursuant to 18 U.S.C: 1001 and/or;(2)immediate termination of Its MOU and/or; (3)possible debarment or suspension. G.The foregoing constitutes the full agreement on this subject between DHS and the Employer. To be accepted as an E-Verlfy participant,you should only sign the Employer's Section of the signature page. If you have any questions, contact E-Verify at 1-888-464-4218. Page 12 of 17 E-Verify MOU for Employers I Revision Date 08/01/13 CAO , ,,,...--"---:. — ''''',.±‘ :;,'44iiii;.,',9', ri- —, !,,.•' ' i, 4i,wii. ... Company ID Number 407348 Approved by: mploysr rC FS Roofing Services,LLC ame(Please Type or Print) Tide Roger LePage Signature Date Electronically Signed 04/08/2011 bepartment of Homeland Sslinty—Verification Division 'Nem e(Please Type or Print) Title USCIS Verification Division Li . gnature - — Date Electronically Signed ,04/12/2011 Page 13 of 17 ENeerfy MOU for Employers 1 RovIsion Dam 06K11/13 fir E-Verify OW i iii1/4 . ,. , �i r Company ID Number 407348 Information Required for the E-Verify Program Information relating to your Company: CFS Roofing Services,LLC company Name 12120 Amedicus Ln ' Fort Myers,FL 33907 company Facility Address Company Alternate Address ,ounty or Parish LEE Employer Identification Number 274953359 North American Industry '.Jiassification Systems Code 238 Parent Company 1 Number of Erriployees 20 to 99 Number of Sites Verified for I Pepe 14 of 17 E-Verlly MOU for Employers(Revision Date 08/01/13 C)_ :1- to-, '44.t.! ,47 •• „lot rEly Company ID Number: 407348 Are you verifying for more than I alte?If yea, please provide the number of a — verified for In each State: FLORIDA 1 elte(a) Pap 15 of 17 E-Vertfy MOU for Employers Revision Date 0';. 1/t3 ,".. . . E1(erify .A :r i 1 ., ..... . .,, Company ID Num bas: 407348 information relating to the Program Administrators)for your Company on policy questions or operational problems: Name David Crowther Phone Number (239)561 -2800 Fax Number (239)481 -1700 Email Address D.crowtherecrowtherservlces.com Name Roger LePage Phone Number (239)561 -2600 Fax Number (239)481 -1700 Email Address R.Lepage!@crowtherservicea.com Page 18 of 17 E-Vertfy MOU for Employers l Revision Date r: +1/13 0 erify1/4 yet/ Company 8)Number. 407348 Page intentionally left blank Page 17 of 17 E-Verify MOD for Employers Revision Date 01801113 C EXHIBIT A-3: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Personnel Category Aaron Manuel Construction Superintendent (239) 246-5541 David Berendt Sr. Project Manager (239) 848-9991 Julian Ferrer Sr. Estimator (239) 565-7806 10 Construction Services Agreement:Revised 072118 EXHIBIT B-1: PUBLIC PAYMENT BOND 19-7589 Bond No. Contract No. 19-7589 KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and , as Surety, located at (Business Address) are held and firmly bound to as Obligee in the sum of ($ _) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of 20 , with Obligee for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this day of 20 , the name of each party being affixed and these presents duly signed by its under-signed representative, pursuant to authority of its governing body. 11 Construction Services Agreement:Revised 072118 CAte Signed, sealed and delivered in the presence of: PRINCIPAL BY: Witnesses as to Principal NAME: ITS: STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20_ by as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary) NAME: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: ATTEST: SURETY: (Printed Name) (Business Address (Authorized Signature) Witnesses to Surety (Printed Name) 12 Construction Services Agreement:Revised 072118 OR As Attorney in Fact (Attach Power of Attorney) Witnesses (Printed Name) (Business Address) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 by , as of Surety, on behalf of Surety. He/She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (Signature) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: 13 Construction Services Agreement:Revised 072118 EXHIBIT B-2: PUBLIC PERFORMANCE BOND 19-7589 Bond No. Contract No. 19-7589 KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and _ as Surety, located at (Business Address) are held and firmly bound to _, as Obligee in the sum of ($ ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of 20 , with Obligee for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract; and 2. Pays Obligee any and all losses, damages, costs and attorneys'fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this B ond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20 , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 14 Construction Services Agreement:Revised 072118 0 Signed, sealed and delivered in the presence of: PRINCIPAL BY: Witnesses as to Principal NAME: ITS: STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 by as of a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: 15 Construction Services Agreement:Revised 072118 ATTEST: SURETY: (Printed Name) (Business Address) (Authorized Signature) Witnesses as to Surety (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) Witnesses (Printed Name) (Business Address) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 , by , as of , a _Surety, on behalf of Surety. He/She is personally known to me OR has produced as i dentification and who did (did not) take an oath. My Commission Expires: (Signature) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: 16 Construction Services Agreement:Revised 072118 EXHIBIT B-3: INSURANCE REQUIREMENTS The Contractor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Contractor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Contractor waive against each other and the County's separate Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Contractor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Contractors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number/contract number and title. The General Liability Policy provided by Contractor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Contractor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Contractor has any self-insured retentions or deductibles under any of the below listed minimum required coverage, Contractor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be Contractor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation, whichever is longer. The Contractor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non-renewal on the part of the insurance carrier or the Contractor. The Contractor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverage or limits received by Contractor from its insurer and nothing contained herein shall relieve Contractor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Contractor hereunder, Contractor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 17 Construction Services Agreement:Revised 072118 Should at any time the Contractor not maintain the insurance coverage(s) required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage(s) and charge the Contractor for such coverage(s) purchased. If Contractor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Contractor under this Agreement or any other agreement between the County and Contractor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage(s) purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverage(s) shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Contractor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Contractor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 18 Construction Services Agreement:Revised 072118 CAO Collier County Florida Insurance and Bonding Requirements Insurance/Bond Type Required Limits 1. Worker's Compensation Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Statutory Limits and Requirements Evidence of Workers' Compensation coverage or a Certificate of Exemption issued by the State of Florida is required. Entities that are formed as Sole Proprietorships shall not be required to provide a proof of exemption. An application for exemption can be obtained online at I 2. LI Employer's Liability $1,000.000 single limit per occurrence 3. ki.4 Commercial General Bodily Injury and Property D: Liability(Occurrence Form) patterned after the current $1,000,000 single limit per occurrence,$2,000,000 a :s gate for Bodily Injury Liability ISO form and Property :e Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. '14 Indemnification To the maximum extent permitted by Florida law,the ContractorNendor shall defend, indemnify and hold harmless Collier County,its officers and employees from any and all liabilities, damages, losses and costs, incl but not limited to, reasonable attorneys'fees and paralegals'fees,to the extent caused by the negligence,recklessness, or intentionally wrongful conduct of the Contractor/Vendor or anyone employed or utilized by the ContractorNendor in the performance of this A - ment. 5. N Automobile Liability $1,000,000 Each Occurrence; Bodily Injury & Property Damage, Owned/Non-owned/Hired;Automobile Included 6. [7:3 Other insurance as noted: ED Watercraft Per Occurrence 1:3 United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. $ Per Occurrence CI Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Per Occurrence 0 Aircraft Liability coverage shall be carried in limits of not less than$5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. $ Per Occurrence 0 Pollution Per Occurrence 0 Professional Liability $ Per claim&in the aggregate 0 Project Professional Liability $ Per Occurrence 0 Valuable Papers Insurance Per Occurrence o Cyber Liability Per Occurrence o Technology Errors&Omissions $ Per Occurrence 7. ri Bid bond Shall be submitted with proposal response in the form of certified funds,cashiers'check or an irrevocable letter of credit,a cash bond posted with the County Clerk,or proposal 19 Construction Services Agreement:Revised 072118 ce bond in a sum equal to 5%of the cost proposal.All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. Performance and For projects in excess of$2001000,bonds shall be submitted with the executed contract Payment Bonds by Proposers receiving award,and written for 100%of the Contract award amount,the cost borne by the Proposer receiving an award.The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner;provided,however,the surety shall be rated as"A-"or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5%of the reported policy holders' surplus,all as reported in the most current Best Key Rating Guide,published by AM Best Company,Inc.of 75 Fulton Street,New York,New York 10038. 9. C. Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. 10. 2 Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required.This insurance shall be primary and non-contributory with respect to any other insurance maintained by,or available for the benefit of,the Additional Insured and the Vendor's policy shall be endorsed accordingly. 11. ,A The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County,OR Collier County Government,OR Collier County. The Certificates of Insurance must state the Contract Number,or Project Number,or specific Project description,or must read: For any and all work performed on behalf of Collier County. 12. On all certificates,the Certificate Holder must read:Collier County Board of Commissioners,3295 Tamiami Trail East, Naples,FL 34112 13. Thirty(30)Days Cancellation Notice required. 14. Collier County shall procure and maintain Builders Risk Insurance on all construction projects where it is deemed necessary.Such coverage shall be endorsed to cover the interests of Collier County as well as the Contractor. Premiums shall be billed to the project and the Contractor shall not include Builders Risk premiums in its project proposal or project billings All questions regarding Builder's Risk Insurance will be addressed by the Collier County Risk Management Division. 3/19/19-CC Vendor's Insurance Statement We tinders m•d the insurance requirements of these specifications and that the evidence of insurability may be required within five(5) days of the award of this solicitation. The ithurank.L submitted must provide coverage for a minimum of six(6)months from the date of award. Name of Firm af7 Trvri ,b1t7)(11 _Lte— Date 5k6(20Pel Vendor Signature Print Name ePAvi i C4141'14,1intYL Insurance Agency Agency ChtluF644or3e • a • • a Agent Name4,ijo, Cyriff , Telephone Number 2? 430 20 Construction Services Agreement:Revised 072118 Di 7 CP ACORD. CERTIFICATE OF,LIABILITY INSURANCE I—Mb •--- ' ---1 I w_ _ ., ...._..._. .��. , � • iii THIS RDA,OF i Ma A 0t TO -.,,,, A On A HOBO AnnTIM mittra maw i , .•':',06t-A . .0I '0.; c;; $.EA LIACI,,r _._ .th&ism :'„ €, 0A$, ,* -z,��,m,.tf eHNHOMODOH a WAN,Napa i Ea Eh offs • . , . �,lsgaih . r hi lhb ea ormr dtar Mt } b tib ft h Neu hook � t �aEnfran iP�f�i • S herr i(mutant*,it v L w 788.8838 Ai e C ta Auto M a „, 2 €�, �' r � - PL 10ii i Yr ' 303/ . Diffiiil Dr •=', 1 l mob 35118 n.c._ naiN iota LA E , ;� ■a Rad •60•060 Nam.. R� 8 moos M TKM a 70 Chula"'hint OF I d • t,E,..�Mill i • A, TO T`tha_ _. ___...._- EXTIMONTE MAY a ,., ER KAY PERTAIN, TAX ItaaNta a an MAIM • N 0 '`10 ML Tia -<+A :NANA AND uounmem OF SAM maxim Limns • WAY NY PAW -:. B Law f :a� f f:r hd 7 .'E.�'it ......_.... 1 t P:.r ori 1v9t «--YI' i 11M10 w $Aper %. >1 expohoLa oht.leow BLOOD ON �.�I * , o NO i.1Tt -WAINTP, , $0,000, . R ,airrn LEMAN X X in, i 8t 1_ .. 1,', . t, I,SCC 0 X fOrY AVM WAIN t =�s 6 X_ 4. A $0,0a,NPD .. I QI i" TON XHamm :i:.11 it"itiil 01f�it K A P A ILL ®1 e_, :tun EL•., - _y .Y+ 4 ':$1 1- �; a^ = cam• �,...�..... _.. _ �.._. MOONS ..,.. 1 $ rati 8 1 8.SIMINMMt r I 1", ono invo..inauLan XX:FAY Wa and: r .: .. i . 1W by on a avimurynon irminnab T <. Ilia, al 5 ki f - bins liner « t 1 n i insured in mo in flay tar FallanlItSiniudinp tAibcty i of Su n. r of t OO,Ftp f 0 ..,,. -CANCELLATION ______ r Doan* or } Nion MEQ 00 BAENA • RATE , ,:.w.•> Iit 01 10 0 1101A T: i 1 N. , ill _.. _ A r aa' I.:.:n::::‘•.:.. X71 1 e 1 Di (Contin s ) iubropolml r rogsnis Am Welkin Compoosslion c AS by edam ooetreit WC00001'01111.-- 30 ML00 Oslo Nodes of tbnoeli dion Es oopt 10 0x Nonpsymat II $ ITA SU MIMw 2 of 2 N10iul0N11i0V170 EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF (COLLIER) STATE OF (FLORIDA) Before me,the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated ,20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed,shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits,actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. CONTRACTOR BY: Witness ITS: President DATE: Witness [Corporate Seal] STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me or has produced as identification and did (did not)take an oath. My Commission Expires: (Signature of Notary) NAME: (Legibly Printed) Notary Public, State of (AFFIX OFFICIAL SEAL) Commissioner No.: 21 Construction Services Agreement:Revised 072118 EXHIBIT D FORM OF CONTRACT APPLICATION FOR PAYMENT Collier County Board of County Commissioners(the OWNER) or Collier County Water-Sewer Owner's Project Bid No. Manager's Name: Project No. County's Division Name Purchase Order No. Submitted by Contractor Application Date: Representative: Name Contractor's Name& Payment Application No. Address: Original Contract Time: Original Contract Price: $ Revised Contract Time: Total Change Orders to Date: $ Revised Contract Amount: $ Total Value of Work Completed & $ Stored to Date: Retainage @10% $ Retainage @ 10%through [Insert $ through [Insert Date] date] Retainage @ % $ Less Retainage $ after[Insert date] Total Earned Less Retainage $ Less previous payment(s) Percent Work Completed % AMOUNT DUE THIS $ to Date: APPLICATION: Percent Contract Time Completed to Date: Liquidated Damages to $ Remaining Contract Balance $ Be Accrued ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,security interests and encumbrances(except such as covered by Bond acceptable to OWNER); (3)all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. Contractor's Name Contractor's Signature: Date: Type Title: Shall be signed by an authorized representative of the Contractor. Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Design Professional's Name: Signature: Date: Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended by: Owner's Project Manager Name: Signature: Date: 22 Construction Services Agreement:Revised 072118 EXHIBIT D(Continued) SCHEDULE OF VALUES Project Name: Project Number: Date: Period To:.. ITEM DESCRIPTION SCHEDULED WORK COMPLETED STORED TOTAL PERCENT BALANCE 10% _% TOTAL NUMBER VALUE MATERIALS COMPLETED COMPLETE TO FINISH RETAINAGE RETAINAGE RETAINAGE PREVIOUS APPLICATIONS THIS &STORED (reduced rate) MTHHELD THRU DATE SINCE DATE PERIOD TO DATE TOTALS Explanation for the two columns under Previous Applications:The Thru Date is where you will place all information until the contract is complete unless a release or reduction of retainage issue col into play.If this happens,all information up to the date of the%change in retainage is placed in the Thru Date column. Information after that date is placed in the Since Date column.This states what has happened since the change in retainage. 23 Construction Services Agreement:Revised 072118 0 Exhibit D (Continued) Stored Materials Record Formula: A+ B- C- D = E A B C D E Invoice Previously Received Previously Installed Balance To Date Description Supplier Number Received This Period Installed This Period Install 24 Construction Services Agreement:Revised 072118 ® i EXHIBIT E: CHANGE ORDER An electronic data entry form may be found at: http://bccspOl/SiteDirectory/ASD/Purchasing/Formsl/Forms/Default.aspx Change Order Form Contract*: Change*: Purchase Order*: Project*: Co ntracto OF'rim Name: Project Name Project Manager Name Department: Otig in al CormactWatkrd ar Amount iginal ecc Approval Date;Agenda Item* Current BCC Approved Amount Last BCC.Aolmoval Date AoenM a Item* Current Contract W ork Order Amount SAP Contract Expiration Date t Master) Dollar Amour t of this Change *C IV DI Total Change from a 1/43 ins!Amount Revised C ontractWorli Or del Total 5 000 %,:r Change from C tiff end ESC Approved Amount CU MS C ha nes S 000 *D1V,)0, Change from C Ler e nt Amount Completion Date, Description of the TaskfM Change,and Rationale for the Change Notice to Proceei OriginalLast Approved Revised Date Date Completion Da= Date , tres Veva of Days Added Select Tasks 0 Add new taskfM Delete tasids) 0 C h a nge tasilds) 0 Other 4'Sae ta0A1 Provide a response to the following:1.idetaileid and specific explanationkatio male of the requ ested shange(s)to the tasids)and if or the additional days added(if requested;2.)why this change was not included in the original contract;and, L)describe the impact if this change is not processed 4<`. r,sOdlhz,ral hformaiion from the Desgh Profess g)rral and/or Co-Ira:1ot rf^seas:. Prepared by: e, (Project Manager Name and Department) Acceptance of this Change Orders hall commit me a modification to contract work order identified above and will be subject to Mitre same terms and conditions as contained in the contract work order indicated above,as fully as if lite same were stated in this acoeptacce. The adjtatment.if anyto it*Cor/ram shall cor stitle a hill and final settlement of any arm all c laims e the Contractor Vendor Cons tiftart; Design.Profess oral arising om of or relateotothechairgeset fonit herein.inck,iding cairns for int ceot and delay costs Accepted by: Date: (Contractor.''Vendor,'Consultant Design Profess one!and Name of Firm.if project applicatie) Approved by: Date: (Design Profes s Kral and Name of Firm,if project applicable) Approved by: Date: ;:ProoLremehrt Professional rs; ,o srnora -o 25 Construction Services Agreement:Revised 072118 , , EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. Design Professional's Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER And To Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER,CONTRACTOR AND DESIGN PROFESSIONAL,and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 26 Construction Services Agreement:Revised 072118 C;\C; RESPONSIBILITIES: OWNER: CONTRACTOR The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20 Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER By: Type Name and Title 27 Construction Services Agreement:Revised 072118 CAO EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: PO No.: Date: Contractor: The following items have been secured by the for the Project known as and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner(attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As-Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14. Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: (Company Name) (Signature) (Typed Name&Title) By Design Professional: (Firm Name) (Signature) (Typed Name&Title) By Owner: (Department Name) (Signature) (Name&Title) 28 Construction Services Agreement:Revised 072118 EXHIBIT H: GENERAL TERMS AND CONDITIONS 1. INTENT OF CONTRACT DOCUMENTS. 1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well-known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and instal led as part of the Work, whether or not called for by the Contract Documents. 2. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work-site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 29 Construction Services Agreement:Revised 072118 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub-Section 2.2 as the"Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. 3. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be 30 Construction Services Agreement:Revised 072118 limited to the hours of 7 a.m. to 7 p.m., Monday through Saturday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.4 Contractor shall submit its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 4.5 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re-submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is 31 Construction Services Agreement:Revised 072118 stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent (50%) completion subject to the guidelines set forth in Florida Statute 255.078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub-subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub-subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non- payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 32 Construction Services Agreement:Revised 072118 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non-liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5.3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off-set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 33 Construction Services Agreement:Revised 072118 7. SUBMITTALS AND SUBSTITUTIONS. 7.1 Contractor shal I carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will 34 Construction Services Agreement:Revised 072118 record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub-Contractor's personnel; 8.1.4 The number of Contractor's and Sub-Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1.8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features 35 Construction Services Agreement:Revised 072118 (e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The "As-Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As-Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 9. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material-men, as well as coordinating its Work with all 36 Construction Services Agreement:Revised 072118 G�� work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work 37 Construction Services Agreement:Revised 072118 Directive Change. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub-subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or sub-subcontractor for field and home office overhead is included in the markups noted above. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight (48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pend ency of any Claim. 38 Construction Services Agreement:Revised 072118 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the ContractorNendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor/Vendor/Consultant or anyone employed or utilized by the Contractor/Vendor/Consultant i n the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit B-3 to the Agreement. 39 Construction Services Agreement:Revised 072118 Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit B-3. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet- based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: • Commodity based procurement where no services are provided. • Where the requirem ent for the affidavit is waived by the Board of County Commissioners Contractors/Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the Contractor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Contractors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the Bidder/Contractor does not comply with providing both the acceptable E-Verify evidence and the executed affidavit the bidder's /Contractor's proposal may be deemed non- responsive. 40 Construction Services Agreement:Revised 072118 Additionally, Contractors shall require all subcontracted Contractors to use the E-Verify system for all purchases not covered under the "Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (E-Verify) program visit the following website: http://www.dhs.qov/E-Verify. It shall be the Contractor's responsibility to familiarize themselves with all rules and regulations governing this program. Contractor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2.3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies when the Contractor is acquiring permits. Owner will not be obligated to pay for any permits obtained by Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 41 Construction Services Agreement:Revised 072118 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default of the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or(3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s)within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials,equipment, supplies, and other items therefore or re-letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 42 Construction Services Agreement:Revised 072118 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below . 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager 43 Construction Services Agreement:Revised 072118 CNC) shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch-list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch-list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: (1) Receipt of Contractor's Final Application for Payment. (2) The Release and Affidavit in the form attached as Exhibit C. (3) Consent of surety to final payment. (4) Receipt of the final payment check list. (5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 44 Construction Services Agreement:Revised 072118 ® I 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections,tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re-inspection fees and costs; to the extent such re-inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight(8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shal I as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non-defective Work. Contractor shall bear all direct, indirect and consequential 45 Construction Services Agreement:Revised 072118 costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstructio n. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall 46 Construction Services Agreement:Revised 072118 include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit A-1 is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.B, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 47 Construction Services Agreement: Revised 072118 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherw ise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, 48 Construction Services Agreement:Revised 072118 Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5.7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5.9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend a pr e-construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work,the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or 49 Construction Services Agreement:Revised 072118 Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre-construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right-of-Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.net/purchasing. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of 50 Construction Services Agreement:Revised 072118 the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be "qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self-performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub-subcontractor performing any portion of the Work, as well as maintain a log of all such licenses.All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of 51 Construction Services Agreement:Revised 072118 under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four(4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e-mail (DL-FMOPS(a�colliergov.net)whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of$500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the Contractor is responsible for all costs. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A"project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid & Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing /will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48-hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials/petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 54 Construction Services Agreement:Revised 072118 S 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision- making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision-making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 55 Construction Services Agreement:Revised 072118 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS "Attached hereto, following this page" 56 Construction Services Agreement:Revised 072118 19-7589—NCWRF Operations Building New Roof— Exhibit I—Scope of Work The project is a roofing project to re-roof an existing two-story building located within the North Collier Water Treatment facility at 10500 Goodlette-Frank Road North.The building houses an essential operation for the treatment plant and Is currently occupied.The building Is to be occupied during the reroofing work,with selective relocations of employees for limited time frames,if necessary.Other work has been contracted for the interior of the building under separate contracts. Mold remediation by others will follow the roof replacement. The roof was damaged by Hurricane Irma.The existing roof system was a clay tile roof that will be replaced with a new metal roofing system.Most of the 2nd floor roof area has'been stripped of clay tile roofing,and the first-floor roof areas still have the tile roofing in place.A temporary paper layer has been installed to keep the building dry.The contractor will be required to maintain the existing roof until the new roof Is complete and water tight and protect the existing facility from water intrusion from the roof for the duration of the project. The work indudes repair of two existing trusses,supplemental reinforcing of truss anchorage as detailed at each truss/tie beam,new metal roofing system complete,and remove and replace the existing lightning protection system. The existing roof decking and any new roof decking replace shall be nailed/re-nailed to comply per Florida Building Code,latest edition.Attachments,fasteners and spacing of fasteners of roof deck, underlayment,secondary moisture barrier,and metal roofing systems shall comply with the Florida Building Code and the manufacturers recommendation. Drywall and Insulation work indicated by notes on the documents will be done by others and not part of the reroofing work. The contractor will be required to provide a 20-year manufacturer's standard warranty on the material and finish, and 1-year workmanship warranty on the installation by the roofing contractor. The Building Permit has been applied for and paid for by Collier County and the contractor will be required to provide product approvals for he underlayment and roofing materials,the commercial contractor acknowledgement form, the submittals and Notice of Commencement,and any other requirements as may be necessary for issuance of the permit. Permit#PRBD20190102652.The Contractor will be responsible for processing the Building Permit. A limited laydown area will be made available to the contractor.This area is identified as the grassy area to the east side of the building and/or the area adjacent to the retention pond to the east of the building,subject to availability and limits of duration.Contractor will be required to secure his own laydown area. Removal and replacement of roof sheathing is expected as part of the truss reinforcing and installation of supplemental truss anchors.Assume 35 sheets of plywood to be removed and replaced.If the roof deck replacement exceeds 35 sheets,a unit price will apply,as indicated on the bid form. Stucco patching and repair is as detailed in the drawings relative to flashing at the dormers,the upper level roof overhangs,the lower level roof overhands,and roofs at the entrance canopy and exterior stairs. Paint stucco patch. The Construction Services Agreement,The Construction Instruction to Bidders Form,and the Purchase Order Terms and Conditions,as posted on BidSync,will be the contract documents. (References to AIA documents as indicated on G100 General Note 45 are not applicable) The Contractor shall visit the site and familiarize himself with the work and conditions of the work prior to submitting a bid. Page 1 of 2 Clarifications and corrections to the drawings 1. G100 Miscellaneous and General Provisions Note 12—Delete note. Drywall not applicable 2. G100 Miscellaneous and General Provisions Note 18—This note is intended that,if in the event that the contractor needs to shore any area of the roof or truss element of the elevation,for whatever reason,that If the contractors engage in the use shoring,the Contractor would need to provide and submit engineer stamped shop drawings. 3. G100 Contingencies Note 1—Delete note.Stucco repair as detailed and necessary for the installation and/or replacement of flashings shall be included in the base bid scope of the work. 4. G100 Contingencies Note 2—Delete note.Plywood roof deck removal and replacement with new roof deck shall be Included in the base bid scope of the work,assuming 35 sheets of plywood to be removed and replaced. If the roof deck replacement exceeds 35 sheets,they will be completed on a unit price will apply,as indicated on the bid form. 5. G100 Contingencies Note 3—Delete note.Unit price for Repair of Damaged Truss does not apply.Truss repair Is identified as two trusses which are detailed on the documents.Should other unforeseen repairs be required,they will be completed on a T&M basis. 6. G100 Contingencies Note 4—Delete note.Hurricane Strap Replacement is indicated on the.drawings.Should other unforeseen Hurricane Strap Replacement become necessary,they will be completed on a unit price basis as provided in the bid form. 7. G100 Contingencies Note 5—Delete note.Any drywall and insulation work indicated by notes on the documents will be done by others and not part of the reroofing work. 8. G100 Contingencies Note 6—Delete note.Nailer does not apply. Lightning Protection System 1. Provide aluminum lightning protection system In accordance with NFPA 780, UL 96/96A, UL 467, and NFPA 70(National Electrical Code). 2. All lightning protection components shall be pass 1. 3. At least two down conductors shall be provided on opposite sides of the building. 4. Grounding connections below grade shall be exothermic weld. 5. Roof mounted loop conductors shall be minimum#1/0 aluminum,fastened at 3-ft maximum Intervals,and bend radius shall not be less than 8" 6. Air terminals shall be installed with max spacing of 25-ft. 7. Air terminals shall be connected with two-way path to each terminal 8. Obtain UL Master Label Certification for the lightning protection system components and installation CFS Roofing Services 04/25/2019 Page 2 of 2 Client#: 74672 CFSRO ACORDn. CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 6/18/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed.If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Sarah ndi Gulfshore Insurance, Inc SWFL PHONE - FAX (A/C,No,Ext):239 43300-7537536 (A/C,No): 239 213-2803 4100 Goodlette Road N E-MAIL sarizmendi@gulfshoreinsurance.com Naples, FL 34103 ADDRESS: @9 INSURER(S)AFFORDING COVERAGE NAIC# 239 261-3646 Cincinnati Specialty INSURER A: p r Underwriters Ins 13037 INSURED INSURER B:Hudson Group 14484 CFS Roofing Services LLC dba Dr Goodroof FRSA-SIF 35378 INSURER C Crowther Holdings Inc Evanston Insurance Company 35378 INSURER D: 12120 Amedicus Ln INSURER E:Federal Insurance Company 20281 Fort Myers, FL 33907 INSURER F: United States Fire Insurance Company 21113 COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDLSUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSR WVD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) LIMITS A GENERAL LIABILITY X X CSU0107348 12/01/2018 12/01/2019 EACH OCCURRENCE $1,000,000 X COMMERCIAL GENERAL LIABILITY PREMISESa RENTED $100,000 CLAIMS-MADE X OCCUR MED EXP(Any one person) $5,000 X BI/PD Ded:10000 PERSONAL&ADV INJURY $1,000,000 GENERAL AGGREGATE $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $2,000,000 POLICYX PRO- LOC $ JECT F AUTOMOBILE LIABILITY X X 1337429844 01/03/2019 12/01/2019 (Ee aBcdeD1SINGLE LIMIT $1,000,000 X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURYPer accident) AUTOS AUTOS ( $ _ X HIRED AUTOS X N -OWNED PROPERTY DAMAGE $ AUTOS (Per accident) XDrive Oth Car $ B UMBRELLA LIAR X OCCUR X X HXS10083402 12/01/2018 12/01/2019 EACH OCCURRENCE $5,000,000 X EXCESS LIAB CLAIMS-MADE AGGREGATE $5,000,000 DED RETENTION$ $ C WORKERS COMPENSATION X 870040136 01/01/2019 01/01/2020 X WCSTATU- OTH- AND EMPLOYERS'LIABILITY Y/N TORY LIMITS ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? N N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 D Excess Liability MKLV7EUE100078 12/01/2018 12/01/2019 $2,000,000 Limit E Leased/Rented 45468685 07/13/2018 12/01/2019 $100,000 Limit Equipment $1,000 Deductible DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(Attach ACORD 101,Additional Remarks Schedule,if more space is required) Project#19-7589-NCWRF Operations Building New Roof. RE: For any and all work preformed on behalf of Collier County. Certificate Holder is included as Additional Insured with regards to General Liability only as required by written contract on a primary noncontributory basis, including ongoing and completed operations per form CSGA437 1213.Waiver of Subrogation in favor of the Additional Insured per form CSGA4087 1212.Additional (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION Collier County Board of SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN County Commissioners ACCORDANCE WITH THE POLICY PROVISIONS. 3295 Tamiami Trail East Naples, FL 34112 AUTHORIZED REPRESENTATIVE -A^77---- ID 77.x! ©1988-2010 ACORD CORPORATION.All rights reserved. ACORD 25(2010/05) 1 of 2 The ACORD name and logo are registered marks of ACORD #S1438357/M1367170 SLA18 DESCRIPTIONS (Continued from Page 1) Insured in regards to Auto Liability per form FM11401378, including Waiver of Subrogation. Waiver of Subrogation in regards to Workers Compensation only as required by written contract WC000313 0484.30 Days Notice of Cancellation Except 10 for Nonpayment. SAGITTA 25.3(2010/05) 2 of 2 #S1438357/M1367170 WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 13 (Ed.4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy.We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Collier County Board of County Commissioners 3295 Tamiami Trail East Naples, FL 34112 This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective Policy No. Endorsement No. Premium 01/01/2019 870-040136 Named Insured Insurance Company CFS Roofing Services, LLC d/b/a/Dr. FRSA Self Insurers Fund, Inc. Goodroof and Crowther Holdings, Inc. 12120 Amedicus Lane Countersigned by Debbie Guidry /♦ r Amok Fort Myers, FL 33907 4 WC 00 03 13 (Ed.4-84) 1983 National Council on Compensation Insurance. COMMERCIAL GENERAL LIABILITY CSGA 4087 12 12 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US - PER CONTRACT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to Paragraph 8.Transfer of Rights of Recovery Against Others to Us of SECTION IV-CONDITIONS: If you have agreed, in a written contract or agreement, to provide a waiver of any right of recovery against a person or organization, we will waive any right of recovery we may have against that person or organization because of payments we make for injury or damage arising out of your ongoing operations or"your work"done under a contract with that person or organization and included in the "products-completed operations hazard". This waiver applies only to that person or organization for which you have agreed to in a written contract to provide said waiver. Includes copyrighted material of Insurance CSGA 408712 12 Services Office, Inc.,with its permission. Page 1 of 1 COMMERCIAL GENERAL LIABILITY CSGA 437 12 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU - OPERATIONS AND COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. SECTION II - WHO IS AN INSURED is amended to include as an additional insured 2. If coverage provided to the additional in- any person or organization when you and such sured is required by a contract or agree- person or organization have agreed in writing ment, the insurance afforded to such ad in a contract or agreement that such person or ditional insured will not be broader than organization be added as an additional insured that which you are required by the con- on your policy, but only with respect to "bodily tract or agreement to provide for such ad- injury", "property damage" or "personal and ditional linsured. advertising injury"caused, in whole or in part, B. With respect to the insurance afforded to by: these additional insureds, the following addi- 1. Your acts or omissions in the perform- tional exclusions apply: ance of your ongoing operations for the This insurance does not apply to: additional insured; 2. The acts or omissions of those acting on 1. "Bodily injury","property damage" or"per- sonal and advertising injury" arising out of your behalf in the performance of your the rendering of, or the failure to render, ongoing operations for the additional in- any professional architectural, engineer- sured; or ing or surveying services, including: 3. "Your work" performed for the additional a. The preparing,approving, or failing to insured and included in the "products- prepare or approve, maps, shop completed operations hazard". drawings, opinions, reports, surveys, If not specified otherwise in the written con- field orders, change orders or draw tract or agreement, a person's or organiza- tion's status as an additional insured under this b. Supervisory, inspection, architectural endorsement ends one year after your opera- or engineering activities. tions for that additional insured are completed. The written contract or agreement must be 2. "Bodily injury" or "property damage" aris- currently in effect or become effective during ing out of 'your work" for which a consoli- the term of this Coverage Part.The contract or dated (wrap-up) insurance program has agreement must be executed prior to the "bod- been provided by the prime contrar- ily injury", "property damage" or "personal and tor/project manager or owner of the con- advertising injury" to which this endorsement struction project in which you are involved. pertains. 3. "Bodily injury", "property damage" or"per- However: sonal and advertising injury" to any em- ployee of you or to any obligation of the 1. The insurance afforded to such additional additional insured to indemnity another insured only applies to the extent permit- because of damages arising out of such ted by law;and injury. Includes copyrighted material of ISO CSGA 437 12 13 Properties, Inc., with its permission. Page 1 of 2 4. "Bodily injury","property damage"or"per- D. With respect to the insurance afforded to sonal and advertising injury' for which the these additional insureds, SECTION IV - Named Insured is afforded no coverage COMMERCIAL GENERAL LIABILITY CON- under this policy of insurance. DITIONS, 4. Other Insurance is amended to C. With respect to the insurance afforded to include: these additional insureds, SECTION III - LIM- Any coverage provided herein will be excess ITS OF INSURANCE is amended to include: over any other valid and collectible insurance available to the additional insured whether The limits applicable to the additional insured primary, excess, contingent or on any other are those specified in the written contract or basis unless you have agreed in a written con- agreement or in the Declarations of this Coy- tract or written agreement executed prior to erage Part, whichever is less. If no limits are any loss that this insurance will be primary. specified in the written contract or agreement, This insurance will be noncontributory only if the limits applicable to the additional insured you have so agreed in a written contract or are those specified in the Declarations of this written agreement executed prior to any loss Coverage Part. The limits of insurance are in- and this coverage is determined to be primary. clusive of and not in addition to the limits of in- surance shown in the Dedarations. Includes copyrighted material of ISO CSGA 437 12 13 Properties, Inc., with its permission. Page 2 of 2 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL AUTOMOBILE BROAD FORM ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM SCHEDULE 1. Broadened Insured Status 14. Audio, Visual,And Data Electronic Equipment 2. Blanket Additional Insured When Required Under Written Contract 15. Loan/Lease Payoff Coverage 3. Employee Hired Autos Liability Coverage 16. Airbag Coverage 4. Employees As Insureds 17. Multiple Deductible Protection — Covered "Auto" And Trailer 5. Coverage Extensions — Supplementary Payments 18. Duties In The Event Of An Accident, Claim, Suit, Or Loss 6. Limited Fellow Employee Coverage 19. Non-Owned Auto Waiver Of Subrogation 7. Limited Hired Auto - Physical Damage Coverage— Private Passenger (Includes 20. Blanket Waiver Of Subrogation When Employee Hired Autos Physical Damage Required Under Written Contract Coverage) 21. Coverage Territory — Short Term Hired 8. Custom Signs And Decoration Commercial"Autos" 9. Extended Towing Coverage 22. Limited Mexico Coverage 10. Glass Breakage 23. Unintentional Failure To Disclose Hazards 11. Reimbursement For Increased Temporary Transportation Expense For Private 24. Mental Anguish Resulting From "Bodily Passenger And Commercial Vehicles Injury" 25. Waiver Of Sovereign Immunity 12. Extra Expense—Stolen Vehicles 26. Application Of This Endorsement 13. Personal Effects Coverage FM 114.0.1378 11 11 Page 1 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. 1. Broadened Insured Status SECTION II - LIABILITY COVERAGE, Paragraph A Coverage, Subparagraph 1. Who Is An Insured is amended to include as an insured: A. Any subsidiary which is a legally incorporated entity of which you own a financial interest of more than 50%of the voting stock on the effective date of this Coverage Form,while using with your permission a covered "auto." However,the insurance afforded by this provision 1.A does not apply to any subsidiary that is an insured under any other automobile liability policy, or would be an insured under such policy but for the termination of such policy or the exhaustion of such policy's limits of insurance. B. Any organization you newly acquire or form,and over which you maintain majority interest, while using with your permission a covered "auto". The insurance afforded by this provision 1.B.: 1. Is effective on the acquisition or formation date,and is afforded only until the end of the policy period of this Coverage Form,or the next anniversary of its inception date, whichever is earlier. 2. Does not apply to "bodily injury"or"property damage" resulting from an "accident" that occurred before you acquired or formed the organization. 3. Does not include any newly acquired or formed organization that is: a. A joint venture or partnership; or b. An insured under any other automobile liability policy, or would bean insured under such policy but for the termination of such policy or the exhaustion of such policy's limits of insurance. 2. Blanket Additional Insured When Required Under Written Contract Paragraph Al.Who Is An ksured under SECTION II—LIABILITY COVERACF is amended to add: d. Any person, organization or governmental entity with respect to the operation, maintenance, or use of a covered "auto" if you are required to add such person, organization or governmental entity to this policy as an additional"insured"in order to comply with the terms of a written contract or written agreement. This Additional Insured status is not conferred when such written contract or written agreement: (1) Involves the owner or anyone else from whom you hire or borrow a covered "auto" unless it is a"trailer"connected to a covered "auto"you own; or (2) Is executed after the date of"accident" or"loss"; Paragraph d.(2)above does not apply if: (a) the terms and conditions of the written contract or written agreement had been agreed upon prior to the "accident" or"loss"; and (b) you can definitively establish that the terms and conditions of the written contract or written agreement ultimately executed are the same as those which had been agreed upon prior to the "accident" or"loss". Paragraph a. of Condition 5. Other Insurance of Part B. General Conditions under Section IV— Business Auto Conditions is amended by the addition of the following: Regardless of whether other insurance is maintained by an additional insured on a primary basis,the coverage provided by Provision 2.of the Commercial Auto Broad Form Endorsement will be primary to and noncontributing with other insurance maintained by the additional insured if the written contract or written agreement between you and the additional insured specifically requires that this insurance be primary. FM 114.0.1378 11 11 Page 2 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. 3. Employee Hired Autos Liability Coverage The following is added to the Who Is An Insured Provision of SECTION II-- LIABILITY COVERAGE: An "employee" of yours is an "insured" while operating an "auto" hired or rented under a written contract or written agreement in that"employee's" name,with your permission,while performing duties related to the conduct of your business. 4. Employees As Insureds The following is added to the Section II - LIABILITY COVERAGE, Paragraph Al.Who Is An Insured Provision: Any "employee"of yours while using with your permission a covered "auto"you don't own, hire or borrow if such "auto" is being used in your business or your personal affairs. 5. Coverage Extensions-Supplementary Payments Paragraphs a.(2)and a.(4)under SECTION II - LIABILITY COVERAGE, Paragraph 2.a. Supplementary Payments are revised as follows: 1. In a.(2), the limit for the cost of bail bonds is increased to S5,000; and 2. In a.(4),the limit for the actual loss of earnings is increased to 51,000 per day. 6. Limited Fellow Employee Coverage The following is added to Subparagraph 5. Fellow Employee under Paragraph B. Exclusions in SECTION II- LIABILITY COVERAGE: But this exclusion does not apply if: a.the"bodily injury" results from the use of a covered "auto"you own or hire,and b.you have Workers Compensation insurance in force covering all of your"employees." Such coverage as is afforded by this provision is excess over any other collectible insurance. 7. Limited Hired Auto- Physical Damage Coverage - Private Passenger(Includes Employee Hired Autos Physical Damage Coverage) The following is added to Subparagraph 1. under Paragraph A. Coverage under SECTION Ill -PHYSICAL DAMAGE COVERAGE: d. Limited Hired Auto- Physical Damage- Private Passenger If hired "autos" are covered "autos"for Liability Coverage,and if Physical Damage Coverage of Comprehensive or Collision is provided under this Coverage Form for any"auto"you own,then Comprehensive and Collision Physical Damage Coverages as provided under SECTION III - PHYSICAL DAMAGE COVERAGE of this Coverage Part are extended to "autos" of the private passenger type you or your employee hires under a written contract or written agreement without a driver,at your direction,for the purpose of conducting your business, subject to the following: (1) The most we will pay for"loss"to any hired "auto"is$35,000 or the actual cash value or cost to repair or replace,whichever is the least, minus a deductible. (2) The deductible will be equal to the largest deductible applicable to any owned "auto" of the private passenger type for that coverage, or$1,000,whichever is less. FM 114.0.1378 11 11 Page 3 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. (3) Limited Hired Auto- Physical Damage - Private Passenger coverage is excess over any other collectible insurance. (4) Subject to the above limit, deductible,and excess provisions we will provide coverage equal to the broadest coverage applicable to any covered "auto"you own of the private passenger type insured under this policy. Coverage includes loss of use of that hired auto, provided it results from an "accident"for which you are legally liable and as a result of which a monetary loss is sustained by the leasing or rental concern. The most we will pay for any one"accident" is S20 per day subject to a maximum of$1,000. If a hmit for Hired Auto - Physical Damage is shown in the Schedule,then that limit replaces, and is not added to,the 535,000 limit indicated above. This extension of coverage does not apply to any "auto"you hire or borrow from any of your "employees", partners (if you are a partnership), members (if you are a limited liability company), or members of their households. 8. Custom Signs And Decoration The following is added to Paragraph A Coverage 1. under SECTION III- PHYSICAL DAMAGE COVERAGE: In the event of a total loss to an "auto" insured for auto physical damage coverage on this policy,in addition to the actual cash value of the"auto", we will pay the actual cost to repair or replace signage or custom paint details up to 85,000. 9. Extended Towing Coverage If the named insured carries Comprehensive and Collision Coverage for the damaged covered commercial "auto", then this coverage extension 9. apples to that covered "auto." If the damaged covered "auto" is of the private passenger type,then in addition to Comprehensive and Collision Coverage,the damaged covered "auto" must also carry Towing Coverage in order for this coverage extension 9.to apply. The following is added to Paragraph Al.Towing under SECTION III- PHYSICAL DAMAGE COVERAGE: We will pay for towing and associated labor costs each time a covered "auto" is disabled. All labor must be performed at the place of disablement. If the"auto" is of the private passenger type, there will be no deductible. If the"auto"is not a private passenger type,a$250 deductible will apply to this coverage but it will not reduce the available limit of insurance. For all types of"autos",the most we will pay under this coverage is $1,000 per disablement. "Autos"which are disabled do not include stolen vehicles. 10. Glass Breakage If you carry Comprehensive Coverage for the damaged covered "auto",then this coverage extension applies to that covered "auto": The following is added to Paragraph A3. Gass Breakage- Hitting A Bird Or Animal -- Falling Objects Or Missiles under SECTION III -PHYSICAL DAMAGE COVERAGE: Any deductible shown in the Declarations will not apply to glass breakage if such glass is repaired, in a manner acceptable to us, rather than replaced. If the glass must be replaced and there is no other damage associated with the"loss",the deductible will be$100 unless a lower deductible is shown on the declarations page for this coverage. FM 114.0.1378 11 11 Page 4 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. 11. Reimbursement For Increased Temporary Transportation Expense For Private Passenger And Commercial Vehicles A If The Covered'Auto" Has Comprehensive Or Specified Causes Of Loss Physical Damage Coverage: Paragraph a.Transportation Expenses under SECTION III - PHYSICAL DAMAGE COVERAGE,A. Coverage, 4.Coverage Extensions is replaced by the following: If your covered "auto" is damaged or stolen and the damage or theft is covered by Comprehensive or Spedfied Causes of Loss coverage provided by this policy,we will pay up to $50 per day subject to a maximum limit of S1,500 for the necessary and actual temporary transportation expenses (including rental reimbursement)incurred by you during the period beginning 24 hours after the theft or damage and ending,regardless of the policy's expiration, a. when the covered "auto" is returned to use or we pay for its "loss" in the event of a total theft of the covered "auto", or b. when the covered "auto" is repaired or replaced, or we pay for its "loss",whichever is earlier in the event of a "loss"due to a cause other than the total theft of the covered "auto." Except with respect to losses pertaining to the total theft of covered "autos" of the private passenger type,this coverage does not apply while there are spare or reserve"autos" available to you. No deductible applies to this coverage. B. If The Covered'Auto" Has Collision Physical Damage Coverage: If your covered "auto" is damaged and the damage is covered by Collision coverage provided by this policy, we will pay up to S50 per day subject to a maximum limit of$1,500 for necessary and actual temporary transportation expenses (including rental reimbursement) incurred by you during the period beginning 24 hours after the"loss"and ending, regardless of the policy's expiration, when the covered "auto" is repaired or replaced, or we pay for its "loss", whichever is earlier. This coverage does not apply while there are spare or reserve"autos" available to you. No deductible applies to this coverage. 12. Extra Expense - Stolen Vehicles The following is added under Paragraph A4.a. Coverage Extensions of SECTION III- PHYSICAL DAMAGE COVERAGE: We will pay for all reasonable and necessary expenses to return a stolen covered "auto"to the named insured if such covered "auto" carries Comprehensive coverage. FM 114.0.1378 11 11 Page 5 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. 13. Personal Effects Coverage Paragraph A. Coverage under SECTION III— PHYSICAL DAMAGE COVERAGE is amended to add the following coverage: Personal Effects Coverage 1. We will pay for"loss" to personal property or effects which are owned by an insured and in or on your covered "auto" at the time of"loss"in the event of a total theft of that covered "auto." 2. Subject to Paragraph C. Limit Of Insurance under SECTION III-- PHYSICAL DAMAGE COVERAGE,we will pay up to S500 for"loss" of personal property or effects in any one "accident" involving total theft of a covered "auto". This insurance will not apply if,at the time of"loss", the covered "auto" is unattended, unless the "loss" is the result of forced entry into the covered "auto" while all doors,windows or other openings are closed and locked and there is evidence of forced entry. Under this extension,we will not pay for"loss" to the following: accounts, bills, currency, deeds,evidences of debt, money, notes or securities; electronic equipment or tapes, records, discs or other similar audio, visual or data electronic devices designed for use with audio, visual or data electronic equipment; jewelry, watches, necklaces, bracelets, gems, gold, platinum, silver,furs; animals, birds, or fish or any motorized vehicle. This coverage will be excess over any other collectable insurance. No deductible applies to this coverage. 14. Audio,Visual,And Data Electronic Equipment The sub-limit in Paragraph C.2.of the Limit of Insurance Provision of SECTION III- PHYSICAL DAMAGE COVERAGE is increased to S1,500. 15. Loan/Lease Payoff Coverage The following is added to Limit of Insurance of SECTION III - PHYSICAL DAMAGE COVERAGE: In the event of a total"loss" to a covered "auto" shown in the schedule or declarations for which Collision and Comprehensive Coverage apply,we will pay any unpaid amount due on the lease or loan for that covered "auto,"less; 1. The amount paid under the Physical Damage Coverage Section of the policy,and 2. Any; a. Overdue lease/loan payments at the time of the"loss"; b. Financial penalties imposed under a lease for excessive use,abnormal wear and tear or high mileage: c. Security deposits not returned by the lessor; d. Costs for extended warranties, Credit Life Insurance, Health,Accident or Disability Insurance purchased with the loan or lease;and e. Carry-over balances from previous loans or leases. This coverage is limited to a maximum of S1,500for each covered "auto". FM 114.0.1378 11 11 Page 6 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. 16. Airbag Coverage If the named "insured" carries Comprehensive and Collision Coverage for the damaged covered "auto", then this coverage extension 16. apples to that covered "auto". The following is added to Subparagraph 3.a. under Paragraph B. Exclusions in SECTION III - PHYSICAL DAMAGE COVERAGE: The accidental discharge of an airbag shall not be considered mechanical or electrical breakdown and therefore shall not be excluded. This provision does not apply to "autos" you hire with a driver and it is excess over any warranty specifically designed to provide this coverage. 17. Multiple Deductible Protection- Covered"Auto"And Trailer If you carry Comprehensive and Collision coverages for the damaged covered "autos", then this coverage extension 17.apples to those covered "autos": The following is added to Paragraph D. Deductible under SECTION III- PHYSICAL DAMAGE COVERAGE: Whenever a covered "auto"and trailer are each damaged in the same "loss"while operating as a combined truck and trailer unit, only one deductible shall apply to the"accident". The larger of the two deductibles shall apply. If another policy or coverage form issued by us, that is not an automobile policy or coverage form,applies to the same"loss"or"accident",the following applies: 1. If the deductible under this Business Auto Coverage Form is not the largest deductible, it will be waived. 2. If the deductible under this Business Auto Coverage Form is the largest deductible, it will be reduced by the amount of the smaller(or smallest) deductible. 18. Duties In The Event Of An Accident, Claim, Suit, Or Loss A. Subparagraph 2.a. under Paragraph A. Loss Conditions in SECTION IV- BUSINESS AUTO CONDITIONS is amended so that your obligations relative to notification requirements apply only when the "accident"or"loss"is known to: 1. You,if you are an individual; 2. A partner,if you are a partnership; 3.A member,if you are a joint venture; 4.An executive officer,insurance manager or any other person designated by you to send notices of"accidents" or"loss"to insurers, if you are a corporation; or 5. A member,if you are a limited liability company. B. Subparagraph 2.b.(2) under Paragraph A Loss Conditions in SECTION IV- BUSINESS AUTO CONDITIONS is amended so that your obligations relative to providing us with documents concerning a claim or"suit"will not be considered breached unless the breach occurs after such claim or"suit" is known to: 1. You,if you are an individual; 2.A partner,if you are a partnership; 3.A member,if you are a joint venture; 4.An executive officer,insurance manager or any other person designated by you to send notices of claims or"suits" to insurers,if you are a corporation; or 5.A member,if you are a limited liability company. FM 114.0.1378 11 11 Page 7 of 10 Includes copyrighted material of Insurance Service Office, Inc. with its permission. 19. Non-Owned Auto Waiver Of Subrogation The following is added to Subparagraph 5. Transfer Of Rights Of Recovery Against Others To Us, under Paragraph A Loss Conditions in SECTION IV-BUSINESS AUTO CONDITIONS: We hereby waive any right of subrogation against any of your officers, directors, or "employees" which might arise by reason of any payment under the insurance afforded by this policy for the operation, maintenance, use, loading, or unloading of non-owned "autos". This waiver extends only to payments in excess of other valid and collectible insurance available to the officer, director, or"employee". 20. Blanket Waiver Of Subrogation When Required Under Written Contract The following is added to Subparagraph 5. Transfer Of Rights Of Recovery Against Others To Us, under Paragraph A. Loss Conditions in SECTION IV- BUSINESS AUTO CONDITIONS: However, we waive any right of recovery we may have against a person, organization or governmental entity when you have waived such right of recovery under a written contract or written agreement provided such written contract or agreement is: 1. currently in effect or becoming effective during the term of this policy; and 2. executed prior to the "accident" or"loss"; or 3. executed after the "accident"or"loss" if: a. the terms and conditions of the written contract or written agreement had been agreed upon prior to the "accident" or"loss"; and b. you can definitively establish that the terms and conditions of the written contract or written agreement ultimately executed are the same as those which had been agreed upon prior to the "accident"or"loss". 21. Coverage Territory- Short Term Hired Commercial"Autos" Paragraph 7. Policy Period, Coverage Territory under Paragraph B. General Conditions in SECTION IV- BUSINESS AUTO CONDITIONS is amended by the addition of the following: The coverage territory is extended to anywhere in the world if: 1. A covered "auto" of the commercial van, pick-up, or truck type is leased, hired, rented or borrowed for a period of 30 days or less; and 2. The"insured's" responsibility to pay damages is determined in a "suit"on the merits,in the United States of America,the territories and possessions of the United States of America, Puerto Rico, or Canada or in a settlement we agree to. We will also cover"loss"to, or"accidents"involving,a covered "auto"while being transported between any of these places. FM 114.0.1378 11 11 Page 8 of 10 Includes copyrighted material of Insurance Service Office, Inc.with its permission. 22. Limited Mexico Coverage WARNING AUTO ACCIDENTS IN MEXICO ARE SUBJECT TO THE LAWS OF MEXICO ONLY- NOT THE LAWS OF THE UNITED STATES OF AMERICA. THE REPUBLIC OF MEXICO CONSIDERS ANY AUTO ACCIDENT A CRIMINAL OFFENSE AS WELL AS A CIVIL MATTER. IN SOME CASES THE COVERAGE PROVIDED UNDER THIS ENDORSEMENT MAY NOT BE RECOGNIZED BY THE MEXICAN AUTHORITIES AND WE MAY NOT BE ALLOWED TO IMPLEMENT THIS COVERAGE AT ALL IN MEXICO. YOU SHOULD CONSIDER PURCHASING AUTO COVERAGE FROM A LICENSED MEXICAN INSURANCE COMPANY BEFORE DRIVING INTO MEXICO. THIS ENDORSEMENT DOES NOT APPLY TO ACCIDENTS OR LOSSES WHICH OCCUR OUTSIDE OF 25 MILES FROM THE BOUNDARY OF THE UNITED STATES OF AMERICA. A Coverage 1. Paragraph 7. Policy Period, Coverage Territory of the General Conditions is amended by the addition of the following: The coverage territory is extended to include Mexico but only for: a. "Accidents" or"losses" occurring within 25 miles of the United States border; and b. Trips into Mexico of 10 days or less. 2. Condition 5. Other Insurance of Part B. General Conditions under Section IV- Business Auto Conditions is replaced by the following: The insurance provided by this Provision 22 will be excess over any other collectible insurance. B. Physical Damage Coverage is amended by the addition of the following: If a "loss"to a covered "auto" occurs in Mexico,we will pay for such "loss" in the United States. If the covered "auto" must be repaired in Mexico in order to be driven, we will not pay more than the actual cash value of such "loss"at the nearest United States point where the repairs can be made. C. Additional Exclusions The following additional exclusions are added: This insurance does not apply: 1. If the covered "auto" is not principally garaged and principally used in the United States. 2. To any "insured" who is not a resident of the United States. 23. Unintentional Failure To Disclose Hazards The following is added to Paragraph B. General Conditions in SECTION IV—BUSINESS AUTO CONDITIONS: If you unintentionally fail to disclose any hazards existing on the effective date of this policy, we will not deny coverage under this Coverage Form because of such failure. However,this provision does not affect our right to collect additional premium due to us as a result of these undisclosed hazards in accordance with our filed rating plans. FM 114.0.1378 11 11 Page 9 of 10 Includes copyrighted material of Insurance Service Office: Inc. with its permission. 24. Mental Anguish Resulting From"Bodily Injury" The definition of"bodily injury"in SECTION V- DEFINITIONS is replaced by the following: "Bodily injury" means physical injury, physical sickness or physical disease sustained by any person,including "mental anguish"or death resulting from any of these. It does not include mental anguish to any person which occurs in the absence of physical injury, physical sickness or physical disease to that person. For the purpose of this provision, the term "mental anguish" shall mean any type of mental or emotional illness or distress. 25. Waiver Of Sovereign Immunity The following provision applies if you are a"governmental entity"or we have added a "governmental entity" to your policy as an additional insured,and the"governmental entity" requires us to obtain permission prior to asserting a defense involving governmental immunity or the jurisdiction of the tribunal over the"governmental entity": We shall not raise any defense involving,in any way,the jurisdiction of the tribunal over the "governmental entity",the immunity of the"governmental entity"or its commissioners, officers, agents or employees,the governmental nature of such entity, or the provisions of any statutes respecting suits against the"governmental entity"without first obtaining express advance permission from the designated representative of the"governmental entity." Application of this provision shall not subject us to liability for any portion of a claim or judgment in excess of the applicable limit of insurance. For the purposes of this provision, "governmental entity" means a state, county, district, municipality,town,township, borough, parish,village, or other political subdivision or governmental agency or subdivision. 26. Application Of This Endorsement The coverage enhancements provided by this endorsement apply to the Business Auto Coverage Form. If your policy includes other endorsements in addition to this Commercial Automobile Broad Form Endorsement,and there is a conflict between any of the terms of such endorsement(s)and this Commercial Automobile Broad Form Endorsement, the terms of the other endorsement(s) shall be given priority and control over the terms set forth in this Commercial Automobile Broad Form Endorsement,even if the terms of such other endorsement(s) have the effect of limiting,excluding or reducing the coverage provided under this Commercial Automobile Broad Form Endorsement. All other terms and conditions remain unchanged. FM 114.0.1378 11 11 Page 10 of 10 Includes copyrighted material of Insurance Service Office, Inc. with its permission.