Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Backup Documents 12/11/2018 Item #11G
ORIGINAL DOCUMENTS CHECKLIST & ROUTING SLIP TO ACCOMPANY ALL ORIGINAL DOCUMENTS SENT TO i THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR SIGNATURE Print on pink paper. Attach to original document. The completed routing slip and original documents are to be forwarded to the County Attorney Office at the time the item is placed on the agenda. All completed routing slips and original documents must be received in the County Attorney Office no later than Monday preceding the Board meeting. **NEW** ROUTING SLIP Complete routing lines#1 through#2 as appropriate for additional signatures,dates,and/or information needed. If the document is already complete with the exception of the Chairman's signature,draw a line through routing lines#1 through#2,complete the checklist,and forward to the County Attorney Office. Route to Addressee(s) (List in routing order) Office Initials Date 1. Risk Risk Management 12.1i Zig 2. County Attorney Office County Attorney Office 111kylicp 4. BCC Office Board of County Commissioners / V2-�\4k 4. Minutes and Records Clerk of Court's Office (2 I� 11% 35111 I 5. Procurement Services Procurement Services PRIMARY CONTACT INFORMATION Normally the primary contact is the person who created/prepared the Executive Summary. Primary contact information is needed in the event one of the addressees above,may need to contact staff for additional or missing information. Name of Primary Staff Ana Reynoso/PURCHASING Contact Information 239-252-8950 Contact/ Department Agenda Date Item was December 11, 2018 Agenda Item Number 11.G. . Approved by the BCC Type of Document CONTRACT Number of Original 2 Attached Documents Attached PO number or account N/A 18-7469 Wood Environmen 1& number if document is Wood Environmental& Infrastructure to be recorded Infrastructure Solutions,Inc. Solutions,Inc. INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable col u i . r chev,r is Yes N/A(Not appropriate. (Initial) Applicable) 1. Does the document require the chairman's original signa e STAMP 0 N/A 2. Does the document need to be sent to another agency for a,ditional si .tures? If yes, N/A provide the Contact Information(Name;Agency;Address; ' .•= en an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be AR signed by the Chairman,with the exception of most letters,must be reviewed and signed by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the AR document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's AR signature and initials are required. 7. In most cases(some contracts are an exception),the original document and this routing slip N/A should be provided to the County Attorney Office at the time the item is input into SIRE. Some documents are time sensitive and require forwarding to Tallahassee within a certain time frame or the BCC's actions are nullified. Be aware of your deadlines! 8. The document was approved by the BCC on 12/11/2018 and all changes made during the meeting have been incorporated in the attached document. The County = . fr=Pt Attorney's Office has reviewed the changes,if applicable. 9. Initials of attorney verifying that the attached document is the version approved by the BCC,all changes directed by the BCC have been made,and the document is ready for the Chairman's signature. G MEMORANDUM Date: December 17, 2018 To: Ana Reynoso, Procurement Services From: Martha Vergara, Sr. Deputy Clerk Minutes & Records Department Re: Contract #18-7469 "Professional Services Agreement" CEI for Big Corkscrew Island Regional Park for Big Corkscrew Island Regional Park Contractor: Wood Environmental & Infrastructure Solutions, Inc. Attached for your records is an original of each referenced document above, (Item #11G) adopted by the Board of County Commissioners on Tuesday, December 11, 2018. The Board's Minutes & Records Department has kept an original as part of the Board's Official Records. If you have any questions, please feel free to contact me at 252-7240. Thank you. Attachment iG PROFESSIONAL SERVICES AGREEMENT Contract# 18-7469 for „ CEI for Big Corkscrew Island Regional Park for Big Corkscrew Island Regional Park CCNA ❑ NON-CCNA THIS AGREEMENT is made and entered into this IgVA day of L-- ,S0201her 20 I a by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY") and Wood Environment&Infrastructure Solutions,Inc. , authorized to do business in the State of Florida, whose business address is 1105 Lakewood Parkway, Suite 300,Alpharetta, GA 3009 (hereinafter referred to as the "CONSULTANT" and/or "CONTRACTOR"). WITNESSETH: WHEREAS, the COUNTY desires to obtain the professional services of the CONSULTANT concerning CEI for Big Corkscrew Island Regional Park for Big Corkscrew Island Regional Park (hereinafter referred to as the "Project"), said services being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and; WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows: ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to COUNTY professional services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the COUNTY for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards and other Page 1 of 32 PSA Single Project Agreement 2017.010 Ver.l 1 1G governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to the COUNTY. 1.5. CONSULTANT designates Nestor Fernandez, CPM a qualified licensed professional to serve as the CONSULTANT's project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without the COUNTY's prior written approval, and if so removed must be immediately replaced with a person acceptable to the COUNTY. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from the COUNTY to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to the COUNTY. 1.7. The CONSULTANT represents to the COUNTY that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the COUNTY's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Page 2 of 32 PSA Single Project Agreement 2017.010 Ver.l GCommunication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. 1.8. In the event of any conflicts in these requirements, the CONSULTANT shall notify the COUNTY of such conflict and utilize its best professional judgment to advise the COUNTY regarding resolution of each such conflict. The COUNTYS approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project. 1.9. The COUNTY reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to CONSULTANT's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the COUNTY reserves the right to make sole determination regarding deductions. After notification of deficiency, if the CONSULANT fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the CONSULTANT. The COUNTY may also deduct or charge the Page 3 of 32 PSA Single Project Agreement 2017.010 Ver.1 , 1G CONSULTANT for services and/or items necessary to correct the deficiencies directly related to the CONSULTANT's non-performance whether or not the COUNTY obtained substitute performance. 1.10. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without the COUNTY's prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph. CONSULTANT shall provide the COUNTY prompt written notice of any such subpoenas. 1.11. As directed by the COUNTY, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real- Time Kinematic) GPS Network as provided by the COUNTY. Information layers shall have common naming conventions (i.e. right-of-way- ROW, centerlines-CL, edge-of-pavement- EOP, etc.), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT 2.1. If authorized in writing by the COUNTY through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in the COUNTY's Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by the COUNTY as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. the COUNTY will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If the COUNTY determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to the COUNTY of the emergency within forty-eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT'S right it otherwise may have had to seek an adjustment to its compensation or time of performance under this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: Page 4 of 32 PSA Single Project Agreement 2017.010 Ver.l 0 hG 2.2. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.3. Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, the COUNTY's schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by the COUNTY when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT's control and fault. 2.4. Providing renderings or models for the COUNTY's use. 2.5. Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting the COUNTY in obtaining such process licensing. 2.6. Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.7. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by the COUNTY, other than visits to the Project site or the COUNTY's office. 2.8. Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2.9. Preparing to serve or serving as a CONSULTANT or witness for the COUNTY in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as part of the Basic Services to be provided herein). 2.10. Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice. ARTICLE THREE THE COUNTY'S RESPONSIBILITIES 3.1. The COUNTY shall designate in writing a project manager to act as the COUNTY's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define the COUNTY's policies and decisions with respect to CONSULTANT's services for the Project. However, the Project Manager is not authorized to issue any verbal or written orders or instructions to the CONSULTANT that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: Page 5 of 32 0PSA Single Project Agreement 2017 010 Ver.1 0 1 16 a. The scope of services to be provided and performed by the CONSULTANT hereunder; b. The time the CONSULTANT is obligated to commence and complete all such services; or c. The amount of compensation the COUNTY is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: a. Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; b. Provide all criteria and information requested by CONSULTANT as to the COUNTY 's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; c. Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT's disposal all available information in the COUNTY's possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; d. Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and e. Provide notice to CONSULTANT of any deficiencies or defects discovered by the COUNTY with respect to the services to be rendered by CONSULTANT hereunder. ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from the COUNTY for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of government or of the COUNTY, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONSULTANT shall notify the COUNTY in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT's services from any cause whatsoever, including those for which the COUNTY may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from the COUNTY. CONSULTANT's sole remedy against the COUNTY will be the right to seek an extension of time Page 6 of 32 PSA Single Project Agreement 2017.010 Ver.1 0 it 1 1742 to its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT's compensation shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the COUNTY hereunder, the COUNTY at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the COUNTY's satisfaction that the CONSULTANT's performance is or will shortly be back on schedule. 4.5. In no event shall any approval by the COUNTY authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by the COUNTY to CONSULTANT be deemed a waiver of any right or claim the COUNTY may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the COUNTY for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the COUNTY to the CONSULTANT; and, as a business practice there are no hourly or material invoices presented, rather, the CONSULTANT must perform to the satisfaction of the COUNTY's Project Manager before payment for the fixed price contract is authorized. Time and Materials: The COUNTY agrees to pay the contractor for the amount of labor time spent by the CONSULTANT 's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's mark-up). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. 5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above. n Grant Funded: .: _ e m. „ .e. _a '. Page 7 of 32 PSA Single Project Agreement 2017.010 Ver.1 hG1 _.-. ._ e . e 'e'.. - .._ Z _ • . e ,W e _ . e agenGY- ARTICLE SIX THE OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by the COUNTY, CONSULTANT shall deliver to the COUNTY copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement("Project Documents"). The COUNTY shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to the COUNTY the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring the COUNTY to pay any additional compensation, CONSULTANT hereby grants to the COUNTY a nonexclusive, irrevocable license in all of the Project Documents for the COUNTY's use on this Project. CONSULTANT warrants to the COUNTY that it has full right and authority to grant this license to the COUNTY. Further, CONSULTANT consents to the COUNTY's use of the Project Documents to complete the Project following CONSULTANT'S termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges the COUNTY may be making Project Documents available for review and information to various third parties and hereby consents to such use by the COUNTY. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder. The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. The COUNTY, or any duly authorized agents or representatives of the COUNTY, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall defend, indemnify and hold harmless the COUNTY, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce Page 8 of 32 PSA Single Project Agreement 2017.010 Ver.l 116 any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 8.1.1. The duty to defend under this Article 8 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the CONSULTANT, the COUNTY and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to CONSULTANT. The CONSULTANT's obligation to indemnify and defend under this Article 8 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the COUNTY or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2. All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3. All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests' provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against the COUNTY for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by the COUNTY applicable to this Project. 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. Page 9 of 32 PSA Single Project Agreement 2017.010 Ver.l 1 16 9.4. CONSULTANT, its subconsultants and the COUNTY shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by the COUNTY, except such rights as they may have to the proceeds of such insurance held by any of them. 9.5. All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements: 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT's own staff, unless otherwise authorized in writing by the COUNTY. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the COUNTY. No provision of this Agreement shall, however, be construed as constituting an agreement between the COUNTY and any such other person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third party any claim or right of action against the COUNTY beyond such as may then otherwise exist without regard to this Agreement. 10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. All personnel, identified in Schedule F shall not be removed or replaced without the COUNTY's prior written consent. 10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the COUNTY. Each subconsultant or subcontract agreement shall preserve and protect the rights of the COUNTY under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the sub consulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub- subconsultants or sub-subcontractors. 10.4. CONSULTANT acknowledges and agrees that the COUNTY is a third-party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between the COUNTY and any subconsultant or subcontractor. Further, all such contracts shall Page 10 of 32 PSA Single Project Agreement 2017.010 Ver.1 40 1 1G provide that, at the COUNTY's discretion, they are assignable to the COUNTY upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS 11.1. CONSULTANT's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the COUNTY arising out of this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANT's services nor payment by the COUNTY shall be deemed to be a waiver of any of the COUNTY's rights against CONSULTANT. ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for the COUNTY to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT's failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT's failure to properly and timely perform the services to be provided hereunder or as directed by the COUNTY, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT's principals, officers or directors, or (d) CONSULTANT's failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT's failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The COUNTY may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that the COUNTY otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against the COUNTY shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below. 12.3. The COUNTY shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such termination for convenience, CONSULTANT'S recovery against the COUNTY shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against the COUNTY, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. Page 11 of 32 PSA Single Project Agreement 2017.010 Ver.l iG 12.4. Upon termination and as directed by the COUNTY, the CONSULTANT shall deliver to the COUNTY all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Article 6, that are in CONSULTANT's possession or under its control. 12.5. The COUNTY shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 12.6. In the event (i) the COUNTY fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) the COUNTY otherwise persistently fails to fulfill some material obligation owed by the COUNTY to CONSULTANT under this Agreement, and (ii) the COUNTY has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving THE COUNTY a second fourteen (14) days written notice of CONSULTANT's intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to the COUNTY of CONSULTANT's intent to terminate this Agreement. If the COUNTY does not cure its default within fourteen (14) days after receipt of CONSULTANT's written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the COUNTY, terminate the Agreement and recover from the COUNTY payment for Services performed through the termination date, but in no event, shall CONSULTANT be entitled to payment for Services not performed or any other damages from the COUNTY. ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. 13.2. ❑ CCNA Projects: In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs supporting the compensation for CONSULTANT'S services to be provided under this Agreement are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees that the original Agreement price and any additions thereto shall be adjusted to exclude any significant sums by which the COUNTY determines the Agreement price was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit costs. All such adjustments shall be made within one (1)year following the end of this Agreement. Page 12 of 32 PSA Single Project Agreement 2017.010 Ver.l 0 116 ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the COUNTY shall be in writing and shall be delivered by hand, email, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following the COUNTY's address of record: Board of County Commissioners for Collier County, Florida Division Director: Damon Grant Division Name: Facilities Management Address: 3335 Tamiami Trail East Suite 101 Naples, FL 34112 Administrative Agent/PM: Leandro A. Goicoechea Telephone: 252-8354 E-Mail(s): Leandro.Goicoechea@colliercountyfl.gov 16.2. All notices required or made pursuant to this Agreement to be given by the COUNTY to the CONSULTANT shall be made in writing and shall be delivered by hand, email or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT's address of record: Company Name: Wood Environment & Infrastructure Solutions, Inc. Address: 1105 Lakewood Parkway, Suite 300 Alpharetta, GA 3009 Authorized Agent: Richardo Fraxedas, PE Attention Name & Title: Office Manager Telephone: 305-525-0079 E-Mail(s): ricardo.fraxedas@woodplc.com Page 13 of 32 PSA Single Project Agreement 2017.010 Ver.1 i 16.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. ARTICLE SEVENTEEN MISCELLANEOUS 17.1. CONSULTANT, in representing the COUNTY, shall promote the best interests of the COUNTY and assume towards the COUNTY a duty of the highest trust, confidence, and fair dealing. 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of the COUNTY. 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 17.8. This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 17.9. The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE • Schedule E CCNA Projects: TRUTH IN NEGOTIATION CERTIFICATE Schedule F KEY PERSONNEL Schedule G Other: Solicitation # 18-7469 , including all Attachment(s), Exhibit(s) &Addendum Consultant's Proposal Page 14 of 32 PSA Single Project Agreement 2017.010 Ver.! 116 17.10. n Grant Funded Projects: a-n the event of any conflict between or among the e .. • _. a-• .• a a: • ' •._.. e _ e e • :• - • : ... ..••••_ r .: terms-of-the-Agreement -pr -ovthe terms of all other Contract Documents; _: •_:_ : ..__ e _ _ .. : .:. ___ _ •... _•_ e :__e_•___ . A e ::••:• e : :. _ . _e. •. ....: : '•.. e •: _e• A.__ .•-. __ ••e e: : e :e •_.. _..e.'__..'.••. w :.._. _ e .e Aw_._-u a. •.- _•._. _ _._ ,._. :_e. _e e •aaee_..e. a: sae •... _e_ •. .. _..e. .e: •: _ s•. _ _ _ _tea •._ CONSULTANT at the COUNTY's discretion. 17.11. Applicability. Sections corresponding to any checked box (U ) expressly apply to the terms of this Agreement. ARTICLE EIGHTEEN APPLICABLE LAW 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE NINETEEN SECURING AGREEMENT/PUBLIC ENTITY CRIMES 19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. • At the time this Agreement is executed, CONSULTANT shall sign and deliver to the COUNTY the Truth-In-Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E. CONSULTANT's compensation shall be adjusted to exclude any sums by which the COUNTY determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by the COUNTY of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity, may not be Page 15 01'32 PSA Single Project Agreement 2017.010 Ver.1 hG1 awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." ARTICLE TWENTY DISPUTE RESOLUTION 20.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached during negotiations to the COUNTY for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by the COUNTY's staff person who would make the presentation of any settlement reached at mediation to the COUNTY's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 20.2. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE 21 IMMIGRATION LAW COMPLIANCE 21.1. By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the COUNTY shall have the discretion to unilaterally terminate this Agreement immediately. (signature page to follow) Page 16 of 32 PSA Single Project Agreement 2017 010 Ver.l hG 1 IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement the day and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS FOR COLLIER COUN Y, FLORIDA, Crystal-E<inzel, Actiiig..Cterk of Courts By: Arm- Date. G� ` By. Attes asfYY3bY airman S , Chairman signature only. Ap ved a o r egality: County Name Consultant: Consultant's Witnesses: Wood Environment&Infrastr ur Salu s,Inc. Lfik Witness ‘ALaU1S/ Lejai Name and Title Name and Title .07,0 4,1-Arip '4W/re Aft SWL gY4-a1 :414- Name and Title Page 17 of 32 lv� PSA Single Project Agreement 2017.010 Ver.I to, hG1 SCHEDULE A SCOPE OF SERVICES following this page (pages 1 through 5 ) Page 18 of 32 PSA Single Project Agreement 2017.010 Ver. 0 11 SCHEDULE A SCOPE OF SERVICES (Agreement#18-7469) Big Corkscrew Island Regional Park Program Management/Construction Management Services Overview Wood Environment and Infrastructure Solutions, Inc. ("Wood" "Consultant' and "Contractor") will act as the Owner's representative throughout the Project's planning and construction phases. Program Management Services will be provided for agreed upon administrative duties, General Program Management, Planning Phase Program Management, Design Phase Program Management, Construction Phase Program Management, Construction Observation and requested miscellaneous support services. Each of the requested services will be provided by Wood working in concert with the County, the County's design Professionals and Contractors. Basic Services Wood will be responsible for administering the Owner's contracts with the Design Professionals and Contractors for the project(s) and the coordination of design efforts and construction to provide a unified, finished product with minimum interference between projects. Wood shall provide professional support in contract scoping, plan reviews, scheduling, scheduling reviews, budgeting, evaluation of completeness of submittals, payment submittals. Using reasonable care and skill consistent with Professional Standards, Wood will review or coordinate reviews of the contract agreements and scope of services with Design Professionals, for completeness and potential conflicts and ambiguities and, in accordance with the Owner's guidance, will direct necessary corrections or revisions pursuant to its review of errors or deficiencies in cost estimates, selection of materials, systems and equipment, construction administration. Wood will provide documentation and control of documents to effect timely performance by the supplier entities. and for support of potential defense of claims or litigation Wood will establish and maintain files of documents, letters, reports, plans, memos, field directives, change orders, clarifications, and meeting minutes pertinent to the program and will provide the Owner with a copies of applicable Program correspondence for the Owner's files. Wood will assemble and maintain a technical library for design drawings, specifications, site based maps, design standards, reference standards, and relevant governmental regulations and policies. During the construction phase, Wood will provide construction observer(s) to verify that critical elements of construction are being complied with and that the general intent of the contract documents are being adhered to. Page 1of5 116 Task 1: Initial Document Controls • Establish and maintain an integrated paper and electronic document control system to assure control of engineering and construction records and information received or produced. • Develop: o Project SharePoint Site o Stakeholder List • Contact information • Levels of Access & Permissions o Project Document Controls& Security Plan o Communication Standards & Procedures o Filling System (Compatible with Owner's System) o Project Library o Forms & Logs (Submittals, RFIs, RCOs, CO, NOC, Etc.) Task 2: Design Review & QA/QC • Project Execution Plan(PEP) • Risk Matrix • Develop Project Master Schedule using the latest version of Microsoft Project • Develop Non-Technical Specifications • Attend NE Consultant Progress Meetings o Meet weekly to review status of work o Review design progress • Project analysis at 100%design development o Constructability Review by Discipline • Deliverable is limited to mark-ups or comments to documents provided by the Design Consultant (No Report Required) o Review of Technical Specifications • Deliverable is limited to comments specifications provided by the Design Consultant(No Report Required) o BIM Modeling for Clash Detection o Meet with design A/E to review comments • Permitting Assistance (Local, State, Federal Permits) o NE is responsible for preparing and submitting permit applications for their projects, attending resulting meetings and for responding to requests for information (RFI)from the jurisdictional agency. o Review and Logging of permits obtained by the Design Consultant from the agencies that have jurisdiction over the project Task 3: Bid Assistance • Review Bid Documents o Design Documents o Technical and Non-Technical Specification Page 2 of 5 hG1 o Bid Tab • Attend Pre-Bid Meeting • Attend Site Walkthrough Task 4: Construction Oversight/Program Management Construction Phase Assumptions: 1. The project will be bid as two separate projects 2. The first project includes the Civil/Horizontal work while the second includes the vertical 3. The duration for each will be 18 months although they are staggered so that civil starts 4 months ahead of vertical 4. Overall construction duration will not exceed 22 months (670 Calendar days) 5. Certification of the work will be provided by others(Designer of Record shall certify the work at both Substantial Completion and at Final Acceptance) 6. Senior Engineer will not be require during construction 7. Project Engineer will not be required on a full time basis 8. Senior inspector will be assigned throughout the construction period with assistance from a lower level inspector only while both projects are in construction 9. Project Scheduler will develop a Master Schedule using the Contractor provided Baseline Schedules which wil be updated monthly using the Contractor's Monthly Progress submittal Scope of Work • Coordinate and attend pre-construction conferences with Owner and NE representative • Coordinate and chair weekly construction progress meetings o Prepare and distribute meeting minutes o Develop and distribute Critical Item Action Lists • Review/Track/Monitor status of o construction progress o shop drawing submittals o contract document clarification and interpretations(RFIs) o respond to RFIs that do not involve design interpretations o requests for changes to construction cost and or schedule • Review of contractor(s) Baseline/Progress schedule • Provide contractor(s)with schedule comments • Update the Master Schedule using the latest version of Microsoft Project • • Processing of Progress Payments o Together with the NE and Owner • Verify that the work has progressed to the point indicated • Verify that the work is in substantial accordance with the contract documents • Verify that the contractor is entitled to the payment in the recommended amount • Verify that the A/E has properly Certified the Request for Payment Page 3 of 5 1 16 • Verify that all required backup documentation such as the appropriate subcontractor and contractor Releases of Lien and the Bonding Company's Consent of Payment are included • Recommend payment • Construction Observation Services o Conduct on-site observations of work in progress to assist in determining if the provisions of the contract documents and permitting conditions are being fulfilled o Report, in writing, whenever it is believed that work is unsatisfactory, faulty or defective o Report, in writing, whenever it is believed that a hazardous condition exists o Note:Wood E&I is not performing as a certified "competent person"on the job site.The contractor shall assign personnel to the job site that have successfully completed training programs related to trench safety, confined space and maintenance of traffic. o Report, in writing, any deviation from the contract documents o Maintain log of the work performed to include: • When the contractor is on the job site • Weather conditions • Changed conditions • List of visitors • Construction Materials Testing activities • General observations • Specific observations • Observed testing procedures o Verify that tests, equipment and systems start up are conducted in the presence of appropriate personnel o Verify that the contractor maintains adequate records o Provide photographic record of construction o Observe materials and workmanship o Verify the sampling and testing of materials are performed by independent testing laboratories o Monitor that record drawing mark-ups are properly maintained • Project closeout o Confirm project completion with appropriate agencies o Verify issuance of Certificate of Occupancy o Coordinate and attend Substantial Completion Walk through o Assist the NE and Owner with development of a "punch list" of items needing completion prior to Final Acceptance o Confirm that punch list items are completed o Coordinate a final review of finished items o Collect necessary documentation to close the project/contract • Lien waivers • Contractor's Final Affidavit • Close-out change orders • Surety's Final Consent • Process Final Payment • As-built Drawings • Provide contractor evaluation • Transmit all Project/Program related files to the County Page 4 of 5 0 Task 5 Reimbursables • Wood will be reimbursed for the direct costs incurred for plotting plans, copies, prints, Travel Expenses, and other expenses in support of the tasks outlined above. These costs will be itemized as they are incurred and pursuant to Schedule B of this Agreement. Task 6 Allowance • An allowance of 10%, as permitted and authorized by the Owner. Tasks 7-9: Extended Construction Oversight The County will issue a separate Notice to Proceed with thirty (30) days for each task. These tasks apply if the County elects to extend the Agreement beyond the original Notice to Proceed issued. Page 5 of 5 116 SCHEDULE B BASIS OF COMPENSATION 1. MONTHLY STATUS REPORTS B.1.1. As a condition precedent to payment, CONSULTANT shall submit to the COUNTY as part of its monthly invoice a progress report reflecting the Project status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1. For the Basic Services provided for in this Agreement, the COUNTY agrees to make the payments to CONSULTANT in accordance with the terms stated below. Payments will be made in accordance with the following Schedule; however, the payment of any particular line item noted below shall not be due until services associated with any such line item have been completed or partially completed to the COUNTY's reasonable satisfaction. Lump sum payments will be made upon the percentage complete. In no event shall such Time and Materials compensation exceed the amounts set forth in the table below. Tasks/Item Description Lump Sum Time and Materials Not-To- Exceed 1 Task 1: Initial Document Controls $ $ $26,480 2 Task 2: Design Review&QA/QC $ $ $111,440 3 Task 3: Bid Assistance Services $ $ $28,440 4 Task 4:Construction Oversight $ $ $1,421,680 5 Task 5: Reimbursables $ $ $13,100 6 Task 6:Allowance $ $ $160,114 7 Task 7: Extended Construction Oversight $ $ $57,020 8 Task 8: Extended Construction Oversight $ $ $57,020 9 Task 9: Extended Construction Oversight $ $ $57,020 $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ Total Lump Sum Fee $ $0 Total Time and Materials Fee $ $ $1,932,314 GRAND TOTAL FEE $ $ $1,932,314 Page 19 of 32 PSA Single Project Agreement 2017.010 Ver.1 hG1 B.2.2. ❑i*Time and Material Fees: The fees noted in Section B.2.1. shall constitute the amounts to be paid to CONSULTANT for the performance of the Basic Services. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT's personnel, with respect to this Project, including all indirect payroll related costs and fringe benefits, all in accordance with and not in excess of the rates set forth in the Attachment 1 to this Schedule B. With each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by the COUNTY, regarding CONSULTANT's Direct Labor Costs incurred at the time of billing, to be reviewed and approved by the COUNTY. There shall be no overtime pay without the COUNTY's prior written approval. B.2.2.1. Notwithstanding anything herein to the contrary, in no event may CONSULTANT's monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task(s) limits by the percentage the COUNTY has determined CONSULTANT has completed such task as of that particular monthly billing. B.2.3. ❑* •• -- ._ ::_ •e e . -_ e. _. .._ _ _ .: _••e __•• _••e_ . to be paid to CONSULTANT for the performance of the Basic Services. There shall be no . - ••: r ma. • ► '..,, e '•e , ' -.• ,,..e....e -E1,2,3A- NT shall submi , :-__ e • e,_• _ _- - •e- '..._. ... e__.... .'_ _.__•:e_- - ,;..• . _..e._: e •-r 'r __r.: e-re ••_ e_t _To_. - -._a w A rr' 'e• _. _:r. :_ e_..-.. '•e et e_.. '•e 0-es .__. B.2.4. For Additional Services provided pursuant to Article 2 of the Agreement, if any, the COUNTY agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided and as set forth in the Amendment authorizing such Additional Services. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provision of Section 3.4.1 below. There shall be no overtime pay on Additional Services without the COUNTY's prior written approval. B.2.5. The compensation provided for under Section B.2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6. Notwithstanding anything in the Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by the COUNTY, pending resolution of the dispute provided that the COUNTY continues to pay to CONSULTANT all amounts that the COUNTY does not dispute are due and payable. Page 20 of 32 PSA Single Project Agreement 2017.010 Vero G 3. SCHEDULE OF PAYMENTS B.3.1. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by the COUNTY. B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this Agreement. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT's letterhead and must include the Purchase Order Number and Project name and shall not be submitted more than one time monthly. B.3.3. Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. B.3.4. Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for this Agreement or Additional Services, CONSULTANT shall be limited to a maximum markup of five percent (5%) on the fees and expenses associated with such subconsultants and subcontractors. B.3.4.1 Reimbursable Expenses must comply with §112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items: B.3.4.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.4.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by the COUNTY. Such expenses, if approved by the COUNTY, may include coach airfare, standard accommodations and meals, all in accordance with §112.061, Fla. Stat. Further, such expenses, if approved by the COUNTY, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.4.1.3. Permit Fees required by the Project. B.3.4.1.4. Expense of overtime work requiring higher than regular rates approved in advance and in writing by the COUNTY. B.3.4.1.5. Expense of models for the County's use. Page 21 of 32 PSA Single Project Agreement 2017.010 Ver.l 110 B.3.4.1.6. Other items on request and approved in writing by the COUNTY. B.3.4.1.7. The CONSULTANT shall bear and pay all overhead and other expenses, except for authorized reimbursable expenses, incurred by CONSULTANT in the performance of the Services. B.3.4.1.8. Records of Reimbursable Expenses shall be kept on a generally recognized accounting basis. B.3.5. The CONSULTANT shall obtain the prior written approval of the COUNTY before incurring any reimbursable expenses, and absent such prior approval, no expenses incurred by CONSULTANT will be deemed to be a reimbursable expense. Page 22 of 32 PSA Single Project Agreement 2017.010 Ver.I �1 hG1 SCHEDULE B —ATTACHMENT 1 CONSULTANT'S HOURLY RATE SCHEDULE Title Hourly Rate Sr.Project Manager $172.00 Sr.Architect $142.00 Architect $121.00 Sr.Engineer $150.00 Engineer $123.00 Estimator/Scheduler $115.00 CAD Technician $81.00 Document Control Clerk $65.00 Sr. Inspector $96.00 Inspector $76.00 The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added via an Amendment upon mutual agreement in advance and in writing by the parties. ` *Grant Funded: The above Page 23 of 32 PSA Single Project Agreement 2017 010 Ver.1 CO)0 G SCHEDULE C PROJECT MILESTONE SCHEDULE Cumulative Number of Calendar Days Task/Item For Completion Description from Date of Notice to Proceed for Services under this Agreement 1 Initial Document Controls 14 days 2 Design Review & QA/QC 31 days 3 Bidding Assistance Services 90 days 4 Construction Oversight 671 days 5 Reimbursables n/a 6 Allowance n/a 7 Extended Construction Oversight 30 days 8 Extended Construction Oversight 30 days 9 Extended Construction Oversight 30 days Page 24 of 32 PSA Single Project Agreement 2017.010 Ver.l I 1G SCHEDULE D INSURANCE COVERAGE 1. The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the below listed minimum required coverages, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be CONSULTANT's sole responsibility. 2. The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. 3. Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the COUNTY oras specified in this Agreement, whichever is longer. 4. Certificates of insurance acceptable to the COUNTY shall be filed with the COUNTY within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance policies required shall be provided to the COUNTY, on a timely basis, if requested by the COUNTY. Such certificates shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the COUNTY. CONSULTANT shall also notify the COUNTY, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer, and nothing contained herein shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. 5. All insurance coverages of the CONSULTANT shall be primary to any insurance or self- insurance program carried by the COUNTY applicable to this Project. 6. The acceptance by the COUNTY of any Certificate of Insurance does not constitute approval or agreement by the COUNTY that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. 7. CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the COUNTY. Page 25 of 32 PSA Single Project Agreement 2017 010 Ver.1 iG 8. Should at any time the CONSULTANT not maintain the insurance coverages required herein, the COUNTY may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse the COUNTY for such costs within thirty (30) days after demand, the COUNTY has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between the COUNTY and CONSULTANT. The COUNTY shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the COUNTY to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Agreement. 9. If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the COUNTY, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the COUNTY with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and the COUNTY may terminate the Agreement for cause. 10. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY. Required by this Agreement? ■ Yes n No Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability - The coverage must include Employers' Liability with a minimum limit of$ 1,000,000 for each accident. The insurance company shall waive all claims rights against the COUNTY and the policy shall be so endorsed. 11. United States Longshoreman's and Harbor Worker's Act coverage shall be maintained where applicable to the completion of the work. Required by this Agreement? Yes n No 12. Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Required by this Agreement? I I Yes • No 13. COMMERCIAL GENERAL LIABILITY. Required by this Agreement? n Yes I I No A. Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Page 26 of 32 PSA Single Project Agreement 2017.010 Ver.1 " G Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the COUNTY of the work under this Agreement. Limits of Liability shall not be less than the following: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, $2,000,000 aggregate. B. The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. 14. Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR, Collier County Government shall be listed as the Certificate Holder and included as an "Additional Insured" on the Insurance Certificate for Commercial General Liability where required. The insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Contractor's policy shall be endorsed accordingly. Contractor shall ensure that all subcontractors comply with the same insurance requirements that the Contractor is required to meet. 15. Watercraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in subparagraph (1) above if applicable to the completion of the Services under this Agreement. Required by this Agreement? ❑ Yes 0 No 16. Aircraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Required by this Agreement? ❑ Yes n No 17. AUTOMOBILE LIABILITY INSURANCE. Required by this Agreement? (i Yes ❑ No Business Auto Liability: Coverage shall have minimum limits of $ 1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include: Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-The ownership. Page 27 of 32 PSA Single Project Agreement 2017.010 Ver.1 0 1 1G 18. TECHNOLOGY ERRORS AND OMISSIONS INSURANCE. Required by this Agreement? ❑ Yes • No Technology Errors and Omissions Insurance: Coverage shall have minimum limits of $ Per Occurrence. 19. CYBER INSURANCE. Required by this Agreement? ❑ Yes • No Cyber Insurance: Coverage shall have minimum limits of$ Per Occurrence. 20. UMBRELLA LIABILITY. A. Umbrella Liability may be maintained as part of the liability insurance of the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverages required herein and shall include all coverages on a "following form" basis. B. The policy shall contain wording to the effect that, in the event of the exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. 21. PROFESSIONAL LIABILITY INSURANCE. Required by this Agreement? (* Yes ❑ No A. Professional Liability: Shall be maintained by the CONSULTANT to ensure its legal liability for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recovery against COUNTY as to any claims under this insurance. Such insurance shall have limits of not less than $ 1,000,000 each claim and aggregate. B. Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT. Deductible amounts are subject to the approval of the COUNTY. C. The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the COUNTY. D. The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or the COUNTY, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to the COUNTY of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify the COUNTY by certified mail, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer. In the event Page 28 of 32 PSA Single Project Agreement 2017.010 Ver.1 1 1 . of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by the COUNTY. 22. VALUABLE PAPERS INSURANCE. In the sole discretion of the COUNTY, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. 23. PROJECT PROFESSIONAL LIABILITY. A. If the COUNTY notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with the COUNTY and the COUNTY's insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT's professional liability policy. If no credit is available from CONSULTANT's current professional policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to the COUNTY. Should no credit accrue to the COUNTY, the COUNTY and CONSULTANT, agree to negotiate in good faith a credit on behalf of the COUNTY for the provision of project-specific professional liability insurance policy in consideration for a reduction in CONSULTANT's self-insured retention and the risk of uninsured or underinsured consultants. B. The CONSULTANT agrees to provide the following information when requested by the COUNTY or the COUNTY's Project Manager: 1. The date the professional liability insurance renews. 2. Current policy limits. 3. Current deductibles/self-insured retention. 4. Current underwriter. 5. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. 6. Cost of professional insurance as a percent of revenue. 7. Affirmation that the design firm will complete a timely project errors and omissions application. C. If the COUNTY elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and the COUNTY will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds. END OF SCHEDULE D Page 29 of 32 PSA Single Project Agreement 2017.010 Ver.1 :,:v•,)* lid •■ This schedule is not applicable. SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida Statutes, Wood Environment & Infrastructure Solutions, Inc. (company's name) hereby certifies that wages, rates and other factual unit costs supporting the compensation for the services of the CONSULTANT to be provided under the Professional Services Agreement, concerning " CEI for Big Corkscrew Island Regional Park for Big Corkscrew Island Regional Park''project is accurate, complete and current as of the time of contracting. BY: TITLE: DATE: Page 30 of 32 PSA Single Project Agreement 2017.010 Ver.l y�) 1 1. 6 SCHEDULE F KEY PERSONNEL Name Personnel Category Percentage of Time` Nestor Fernandez Senior Project Manager 13.39% Angel Rodriguez Project Engineer 17.32% Melissa Santiesteban Document Control 20.44% Scott Malloy Senior Inspector 23.09% John Estenoz Inspector 12.93% John Lockstedt Scheduler 5.08% Jose Millian CAD 0.64% Gerkys Triana CAD 0.64% Jason Alphonso Mechanical/Plumbing Engineer 0.06% Jason Page Electrical Engineer 0.06% David Soler Civil Engineer 0.06% Jocelyn Isaias Architect 0.46% Cesar Rullier Architect 0.46% John Hart Electrical Inspector 2.42% Bob Cook Plumbing Inspector 2.42% Augusto Poitevin Structural Engineer 0.06% Page 31 of 32 PSA Single Project Agreement 2017 010 Ver.1 116 SCHEDULE G Other: (Description) ❑ following this page (pages through ) • this schedule is not applicable Page 32 of 32 PSA Single Project Agreement 2017.010 Ver.l e hG1 ._........„,, . '°` CERTIFICATE OF LIABILITY INSURANCE DAT 11I28200118YYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed.If ' SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this i.12 certificate does not confer rights to the certificate holder in lieu of such endorsement(s). '_ PRODUCER CONTACT m,o Aon Risk Services Southwest, Inc. NAME: Houston TX Office (A/CNNo.Ext): (866) 283-7122 (aC No): (800) 363-0105ty 5555 San Felipe E-MAIL O Suite 1500 ADDRESS: _ Houston TX 77056 USA INSURER(S)AFFORDING COVERAGE NAIC# INSURED INSURER A: ACE American Insurance Company 22667 Wood Group USA. Inc. INSURER B: Agri General Insurance Company 42757 fka Amec Foster wheeler 17325 Park Row INSURER C: ACE Fire underwriters Insurance Co. 20702 Houston TX 77084 USA INSURER D: AIG Specialty Insurance Company 26883 INSURER E: Lloyd's Syndicate No. 2003 AA1128003 INSURER F: COVERAGES CERTIFICATE NUMBER: 570073995241 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. Limits shown are as requested INSR ADM.SUBR POLICY EFF POLICY EXP TYPE OF INSURANCE POLICY NUMBER r / LIMITS LTR INSD WVD MM/DD MMIDD A X COMMERCIAL GENERAL LIABILITY Y HD0G27874265 5/01/2018 01/31/2019 EACH OCCURRENCE $1,000,000 DAMAGE TO RENTED — CLAIMS-MADE X OCCUR $1,000,000 PREMISES(Ea occurrence) MED EXP(Any one person) $5,000 PERSONAL&ADV INJURY $2,000,000 v GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 rn PRO- POLICY X JECT I LOC PRODUCTS-COMP/OPAGG $4,000,000 M OTHER: 0 0 r A AUTOMOBILE LIABILITY ISA H25150132 05/01/2018 01/31/2019 COMBINED SINGLE LIMIT $1,000,000 to (Ea accident) X ANY AUTO BODILY INJURY(Per person) o OWNED —SCHEDULED AUTOS ONLY AUTOS BODILY INJURY(Per accident) d HIRED AUTOS NON-OWNED PROPERTY DAMAGE Ill ONLY _AUTOS ONLY (Per accident) I,= t N A X UMBRELLALIAB X OCCUR X0OG24876238009 05/01/2018 01/31/2019 EACH OCCURRENCE $1,000,000 0 — EXCESS LIAR CLAIMS-MADE AGGREGATE $1,000,000 DED X RETENTION 510,000 A WORKERS RS' OMPENSA ION AND WLRc64625196 05/01/2018 01/31/2019 X I STATUTE I IOTH EMPLOLIABILITY Y/N work Comp- AOS ANY PROPRIETOR/PARTNER/EXECUTIVE B OFFICER/MEMBER EXCLUDED? NE.L.EACH ACCIDENT $1,000,000 NIA WLRC64625202 05/01/2018 01/31/2019 (Mandatory in NH) Work Comp- TN E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000— E Archit&Eng Prof PSDEF1800726 07/01/2018 06/30/2019 Any One Claim $1,000,000 Professional Liability Aggregate Limit $1,000,000 SIR applies per policy terms & conditions DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) �_� SEE ATTACHED ADDENDUM FOR ADDITIONAL NAMED INSURED AMEC COMPANIES. RE: Contract #18-7469 CEI for Big Corkscrew Island Regional Park. collier County Board of county commissioners, or Board of county Commissioners in collier County, or collier County Government, or Collier County are included as Additional Insured in accordance with the policy provisions of the General Liability and Automobile Liability policies. General Liability policy evidenced herein is Primary and Non-Contributory to other insurance available to an Additional Insured, but only in accordance with the policy's provisions. r CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE .e POLICY PROVISIONS. c. Collier County Board of County AUTHORIZED REPRESENTATIVE Commissioners 3295 Tamiami Trail E. tStie• (92 :sem cft � Naples FL 34112 uSA U !� { IIII ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD I 116 AGENCY CUSTOMER ID: 570000021966 LOC#: '4 ADDITIONAL REMARKS SCHEDULE Page _ of AGENCY NAMED INSURED Aon Risk Services Southwest, Inc. wood Group USA, Inc. POLICY NUMBER See Certificate Number: 570073995241 CARRIER NAIC CODE see Certificate Number: 570073995241 EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance INSURER(S)AFFORDING COVERAGE NAIC# INSURER INSURER INSURER INSURER ADDITIONAL POLICIES If a policy below does not include limit information,refer to the corresponding policy on the ACORD certificate form for policy limits. POLICY POLICY INSR ADDL SUBR EFFECTIVE EXPIRATION LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER DATE DATE LIMITS (MM/DD/YYYY) (MM/DD/YYYY) WORKERS COMPENSATION C N/A RWCC64785825 05/01/2018 01/31/2019 Work Comp- WI OTHER D Env Site/Poll cPL12456119 05/01/2018 05/01/2019 Each Loss $1,000,000 Pollution Liability Aggregate $1,000,000 Limit ACORD 101(2008/01) ©2008 ACORD CORPORATION.All rights reserved. The ACORD name and logo are registered marks of ACORD 11G AGENCY CUSTOMER ID: 570000021966 LOC#: AL ADDITIONAL REMARKS SCHEDULE Page _ of _ AGENCY NAMED INSURED Aon Risk Services Southwest, Inc. wood Group USA, Inc. POLICY NUMBER See Certificate Number: 570073995241 CARRIER NAIC CODE See Certificate Number: 570073995241 EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance Additional Named Insured & FKA Named Insureds: Amec Foster wheeler Amec Foster Wheeler E&I, Inc. AGRA Pipeline Professionals, Inc. AMEC AES AMEC Civil, LLC AMEC Construction Management, Inc. AMEC E&I, Inc. Amec Foster wheeler AES Inc. (formerly AMEC AES, Inc.) AMEC E&E, P.C. AMEC Earth and Environmental, Inc. AMEC Engineering and Consulting of Michigan, Inc. AMEC Environment & Infrastructure, Inc. Amec Foster wheeler USA corporation Amec Foster Wheeler Programs Inc. Amec Foster Wheeler Constructors, Inc. Amec Foster Wheeler Energia, S.L.U. Amec Foster Wheeler E&C Services, Inc. (formerly AMEC E7C Services, Inc.) Amec Foster wheeler E&I, Inc. Amec Foster Wheeler Industrial Power Company, Inc. AMEC Massachusetts, Inc. Amec Foster Wheeler Martinez Inc. Amec Foster Wheeler North America Corp Amec Foster Wheeler Ventures, Inc. (formerly National Ventures, Inc.) AMEC NNC USA, Inc. AMEC Nuclear USA Inc. AMEC Offshore, Inc. Amec Foster Wheeler Oil and Gas, Inc. (formerly AMEC Oil & Gas, Inc.) AMEC Paragon Inc. AMEC PLC AMEC Technologies, Inc. Amec Foster Wheeler USA Corporation AMEC USA Holding, Inc. Foster Wheeler Intercontinental Corporation OEST Associates, Inc. Amec Foster Wheeler Kamtech, Inc. (formerly AMEC Kamtech, Inc.) MACTEC Engineering and Consulting, P.C. North American Shared Services (NASS) QED International LLC Rider Hunt International USA, Inc. Terra Nova Technologies, Inc. (TNT) Oil & Gas US, Central & South America Wood Group USA, Inc. wood Group Alaska, Inc. Wood Group PSN, Inc. Altablue, Inc. Cape Software, Inc. BMA Solutions, Inc. Global Performance, LLC John Wood Group PLC RWG (Repair & Overhauls) USA, Inc. SgurrEnergy, Inc. Ingenious, Inc. Mustang Process and Industrial Mustang International, LP Mitchell's Oil Field Services, Inc. C.E.C. Controls Company, Inc. Wood Environment & Infrastructure Solutions Inc. Wood E&IS, Inc. ACORD 101(2008/01) ©2008 ACORD CORPORATION.All rights reserved. The ACORD name and logo are registered marks of ACORD u 1 s AGENCY CUSTOMER ID: 570000021966 LOC#: '4COR C:0® ADDITIONAL REMARKS SCHEDULE Page _ of _ AGENCY NAMED INSURED Aon Risk Services Southwest, Inc. Wood Group USA, Inc. POLICY NUMBER See Certificate Number: 570073995241 CARRIER NAIC CODE See Certificate Number: 570073995241 EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance Additional Named Insured & FKA Formerly Known As: AMEC Foster Wheeler Environment & Infrastructure, Inc.(formerly AMEC Environmernt & Infrastructure, Inc.) wood Group Mustang, Inc. Wood Group Kenny, Inc. Wood Group Management Services, Inc. ODL, Inc. Wood Group Production and Consulting Services, Inc. Wood Group PSN Commissioning Services, Inc. Wood Group PSN Lease Maintenance & Construction, LLC DSI Deepwater Specialists, Inc. Caliber Services, LP Infinity Construction Services, LP Infinity Maintenance Services, LP United Electrical & Instrumentation, Ltd. Brazos M&E, Ltd. Elkhorn Holdings, Inc. Elkhorn Construction, Inc. Elkhorn Pipeline Services HOAD ProSafe Dynamic Services ACORD 101(2008/01) ©2008 ACORD CORPORATION.All rights reserved. The ACORD name and logo are registered marks of ACORD