The URL can be used to link to this page

Backup Documents 04/13/2010 Item #16B1116B 11 MEMORANDUM Date: April 27, 2010 To: Brenda Brilhart, Purchasing Agent Purchasing Department From: Teresa Polaski, Deputy Clerk Minutes & Records Department Re: Contract #09 -5328: "Asphalt, Milling & Related Items" Contractor: Better Roads Attached please find the original contract document, as referenced above, (Agenda Item #161111) approved by the Board of County Commissioners on Tuesday, April 13, 2010. The Minutes & Records Department has also retained an original copy which will be kept as part of the Board's permanent record. If you should have any questions, please contact me at 252 -8411. Thank you. Attachments 16B II ITEM NO.: (U�1'' ��S°I DATE RECEIVED: y FILE NO.: b ROUTED TO: C DO NOT WRITE ABOVE THIS LINE n / REQUEST FOR LEGAL SERVICES ` 4 k Date: April 20, 2010 501-T To: County Attorney's Office "Ni y Jeff Klatzkow, County Attorney 1,, From: Brenda Brilhart, Purchasing Agent Purchasing Department, Extension 8446 Re: Contract: #09 -5328 "Asphalt, Milling & Related Items" Contractor: Better Roads BACKGROUND OF REQUEST: This Contract was approved by the BCC on April 13, 2010, Agenda Item 16.B.11 This item has not been previously submitted. ACTION REQUESTED: Contract review and approval. OTHER COMMENTS: This is a standard contract with no changes. Please forward to the BCC for signature after approval. If there are any questions concerning the document, please contact me. Purchasing would appreciate notification when the documents exit your office. Thank you. C: Alex Blanco, Road & Bridge V * xl,s # UPZ C- --C LS_C( CIIECICLIS'F FOR REVIEWING CONTRACTS Entity Name: Entity name correct on contract? No Entity registered with FL Sec. of State? es No Insurance Insurance Certificate attached? _ ✓_ yes No Insured registered in Florida? Y JM No Contract # & /or Project referenced on Certificate? No Certificate Holder name correct (BCC)? � "yes No Commercial General Liability General Aggregate Required $ Provided $s��*�� Exp. Date © I� 0 Products /Compl /Op Required $' Provided $1e f Exp. Date _ Personal & Advert Required $� Provided $ L Exp. Date ti l Each Occurrence Required _y) �_` Provided $ 'C e Exp. Date Firc/Prop Damage Required $__ Provided $� Exp. Date Automobile Liability 1 T Bodily Inj & Prop Required $ j� t Provided $ 22 r' 1 Exp Date Workers Compensation le, ox• G "S eq (A- a_a: `1 Each accident Ruired $. v k� Provided $ �` Lxp Date Q Disease Aggregate Required $__ Provided $ et Exp Date _ Disease Each Empl Required $ Provided $— •e '_I Exp Date r Umbrella Liability Each Occurrence Provided $ 5m, M Exp Date _ n 10 Aggregate Provided $_ It r t Exp Date (-L r 1 Does Umbrella sufficiently cover any underinsured portion? XYes No Professional Liability 'Ir Each Occurrence Required $ Provided $ _ Exp. Date Per Aggregate Required $_ _ Provided $_ _ Exp. Date__ Otherinsurance -- ` Each Occur TypeQl� Required $Provided $ `J 1� Exp Date d hb County required to be .p ame as a thonal ,Wred? ,"y,, No County named as additional insured? �es No Indemnification Does indemnification meet County standards? /Yes No Is County indemnifying other party? __Yes Performance Bond Bond requirement referenced in contract? No If attached, expiration date of bond _Yes _ Does dollar amount match contract? No Agent registered in Florida? ___Yes Yes No Signature Blocks Correct executor name in signature block? Yes No Correct title of executor? Executor authorized to sign for entity? �fe No _ es No Proper number of witnesses /notary? Y s No Authorization for executor to sign, if necessary: _ _ Chairman's signature block? No Clerk's attestation signature block? Y No County Attorney's signature block? _ es No Attachments / Areal] required attachments included? — —��(es No 1/)/ Reviewer Initials' _ Date: 1- 04- C'OA-010 /222 MEMORANDUM TO: Ray Carter Risk Management Department FROM: Brenda Brilhart, Purchasing Agent^ Purchasing Department` DATE: April 20, 2010 RE: Review of Insurance for Contract: #09 -5328 "Asphalt, Milling & Related Items" Contractor: Better Roads This Contract was approved by the BCC on April 13, 2010, Agenda Item 16.6.11 Please review the Insurance Certificates for the above referenced contract. If you have any questions, please contact me at extension 8446. Thank you. C: Alex Blanco, Road & Bridge 16B11 DAh WIMVED APR 21 2010 RISK .l AVaENEK Vo mause From: RaymondCarter Sent: Wednesday, April 21, 2010 2:24 PM To: BrilhartBrenda Cc: mausen_g, HerreraSandra, BlancoAlexander Subject: Contract 09 -5328 "Asphalt, Milling & Related Items" All, I have approved the certificate of insurance provided by Better Roads for contract 09 -5328. The cori will now be forwarded to the county attorney's office for their review. Thank you, Ray RMV"L07Ld Manager Risk Finance Office 239 - 252 -8839 Cell 239- 821 -9370 Under Florida Law, e -mail addresses are public records. If you do not want your e -mail address released in response to a public records request, do not send electronic mail to this entity. Instead, contact this office by telephone or in writing. www.sunbiz.org - Department of State Home Contact Us E- Filing Services Previous on List Next on List Return To List No Events No Name History Detail by Entity Name Florida Profit Corporation BETTER ROADS INC. Filing Information Document Number G58146 FEI /EIN Number 592319514 Date Filed 09/02/1983 State FL Status ACTIVE Principal Address 1910 SEWARD AVE NAPLES FL 34109 US Changed 04/07/2003 Mailing Address 1910 SEWARD AVE NAPLES FL 34109 US Changed 04/07/2003 Registered Agent Name & Address BONNESS, JOSEPH D III 1910 SEWARD AVE NAPLES FL 34109 US Name Changed: 02/23/2009 Address Changed: 04/07/2003 Officer /Director Detail Name & Address Title VS RESTING, JOSEPH M 1910 SEWARD AVENUE NAPLES FL 34109 Title CEOP BONNESS, JOSEPH D III 1910 SEWARD AVENUE NAPLES FL 34109 Title S �ASEY,CAROLYN V 1910 SEWARD AVENUE Document Searches it of 3. Forms Help Entity Name Search r Submit http: / / www.sunbiz.org/ scripts /cordet.exe? action= DE7'FIL &inq_doc_ number= G58146 &in... 4/13/2010 AGREE MEN T09 -5328 for Asphalt, Milling & Related Items THIS AGREEMENT is made and entered into this 13th day of April 2010, by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "County" or "Owner ") and Better Roads, Inc., authorized to do business in the State of Florida, whose business address is 1910 Seward Avenue, Naples Florida 34109 (hereinafter referred to as the "Contractor "). WITNESSETH: 1. COMMENCEMENT: The contract shall be for a one (1) year period, commencing on April 13, 2010, and terminating April 12, 2011, or until such time as all outstanding Purchase Orders issued prior to the expiration of the Agreement period have been completed. This contract shall have three one (1) year renewals, renewable annually. The County Manager, or his designee, may, at his discretion, extend the Agreement under all of the terms and conditions contained in this Agreement for up to one hundred eighty (180) days. The County Manager, or his designee, shall give the Contractor written notice of the County's intention to extend the Agreement term not less than ten (10) days prior to the end of the Agreement term then in effect. 2. STATEMENT OF WORK: The Board of County Commissioners deemed two (2) firms to be pre - qualified and awarded a Contract to each firm on a Primary/Secondary basis. Each awardee will enter into an Agreement to provide complete services for asphalt, milling and related services on an as- needed basis as may be required by the Owner in accordance with the terms and conditions of ITB 09 -5328 and the Contractor's proposal, which is incorporated by reference and made an integral part of this Agreement. The execution of this Agreement shall not be a commitment to the Contractor that any work will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the Quotation procedure outlined in the next paragraphs and all Work undertaken by Contractor for Owner pursuant to this Agreement and that procedure during the term and any extension of the term of this Agreement. For non - emergency work, the Owner shall provide a summary of Work to be performed which will afford the Contractor the opportunity to submit a formal quotation for the new work. The work shall consist of one or more individual work assignments, or groupings of work assignments. The Contractor shall respond with the information sought within seven (7) working days. A purchase order for the quoted work will be awarded to the primary Contractor if that Contractor is able to complete the non - emergency work in the timeframe and within the budget required by the County. If the primary contractor cannot meet the required timeframe and /or budget, a quote will be obtained from the secondary Contractor. In each Request for Quotation, the Owner reserves the right to specify the period of completion and the collection of liquidated damages in the event of late completion. 3. THE CONTRACT SUM: The Owner shall pay the Contractor for the performance of the Work pursuant to the quoted price based on unit prices offered by the Contractor at time of bid. Any Page -1- 16311 County agency may utilize the services offered under this contract, provided sufficient funds are included in its budget(s). 4. NOTICES: All notices required or made pursuant to this Agreement to be given by the County to the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following Contractor's address of record: Joseph M. Restino, Vice President Better Roads, Inc 1910 Seward Avenue Naples, FL 34109 Phone: (239) 597 -2181 All notices required or made pursuant to this Agreement to be given by the Contractor to the County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following County's address of record: Collier County Government Complex Purchasing Department 3301 East Tamiami Trail Purchasing Building G Naples, Florida 34112 Attention: Stephen Y. Carnell Purchasing /General Services Director Phone: 239 - 252 -8371 Fax: 239 - 252 -6584 The Contractor and the County may change the above mailing address at any time upon giving the other party written notification. All notices under this Service Agreement must be in writing. 5. NO PARTNERSHIP: Nothing herein contained shall create or be construed as creating a partnership between the County and the Contractor or to constitute the Contractor as an agent of the County. 6. PERMITS: LICENSES: TAXES: In compliance with Section 218.80, Florida Statutes, all permits necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all such permits issued by the County shall be processed internally by the County. Contractor is not responsible for paying for permits issued by Collier County, but is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier county agencies when the Contractor is acquiring permits. All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. Page -2- 16811 7. NO IMPROPER USE: The Contractor will not use, nor suffer or permit any person to use in any manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation, or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the event of such violation by the Contractor or if the County or its authorized representative shall deem any conduct on the part of the Contractor to be objectionable or improper, the County shall have the right to suspend the Contract of the Contractor. Should the Contractor fail to correct any such violation, conduct, or practice to the satisfaction of the County within twenty -four (24) hours after receiving notice of such violation, conduct, or practice, such suspension to continue until the violation is cured. The Contractor further agrees not to commence operation during the suspension period until the violation has been corrected to the satisfaction of the County. 8. TERMINATION: Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County and requirements of this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a seven (7) day written notice. The County shall be sole judge of non - performance. 9. NO DISCRIMINATION: The Contractor agrees that there shall be no discrimination as to race, sex, color, creed or national origin. 10. INSURANCE: The Contractor shall provide insurance as follows: A. Commercial General Liability: Coverage shall have minimum limits of $5,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent contractors; Products and Completed Operations and Contractual Liability. B. Business Auto Liability: Coverage shall have minimum limits of $2,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include Owned Vehicles, Hired and Non -Owned Vehicles and Employee Non - Ownership. C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in compliance with the applicable state and federal laws. The coverage must include Employers' Liability with a minimum limit of $1,000,000 for each accident. Special Requirements: Collier County Board of County Commissioners shall be listed as the Certificate Holder and included as an Additional Insured on the Comprehensive General Liability. Current, valid insurance policies meeting the requirement herein identified shall be maintained by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification to the County in the event of cancellation or modification of any stipulated insurance coverage. Contractor shall insure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Contractor shall provide County with certificates of insurance meeting the required insurance provisions. Page -3- 16BIl 11. INDEMNIFICATION: To the maximum extent permitted by Florida law, the Contractor/Vendor/ Consultant shall indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor/Vendor /Consultant or anyone employed or utilized by the Contractor/Vendor /Consultant in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 12. BONDS. A. When a construction project is in excess of $200,000, the Contractor(s) shall be required to provide Payment and Performance Bonds. B. When required by Owner, the Contractor shall furnish a Performance and /or Payment Bond prior to commencing performance, for the full amount of the Work, which shall act as a security guaranteeing the performance of the Contractor's work and the payment by the Contractor to any other party (ies) providing labor and /or materials in connection with each construction or renovation project performed by the Contractor. The bonds shall be furnished using the forms prescribed in Exhibit "A ". C. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute another bond and surety, both of which shall be subject to the Owner's approval. 13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in excess of thirty (30) days, the Contractor may indicate on his response to the Request for Quotation the wish to receive Progress Payments. Subsequent to the first payment, Contractor must provide Owner with a fully executed Release and Affidavit in the form attached hereto as Exhibit "B" as a condition precedent to release of each progress payment. All applications for payment, whether for full payment or a progress payment shall be in writing, and in substantially the form attached hereto as Exhibit "C ". 14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or portions thereof, because of defective or incomplete work, outstanding punchlist items, subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence indicating probable fling of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents. Page -4- 16811 If any conditions described above are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 15.SUBMITTALS AND SUBSTITUTIONS. Any substitution of products /materials from specifications shall be approved in writing by Owner in advance. 16. CONTRACT TIME AND TIME EXTENSIONS. A. Time is of the essence in the performance of any Work under this Agreement and Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and materialmen, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's supplies and contractors. B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty -eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. C. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 17. CHANGES IN THE WORK. Owner shall have the right at anytime during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any modifications to this Contract shall be in compliance with the County Purchasing Policy and Administrative Procedures in effect at the time such modifications are authorized. Page -5- 16$11 18.COMPLIANCE WITH LAWS. Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, workers' compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Owner in writing. 19.CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 20.ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 21.WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any materialmen supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after final completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 22.STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on County projects who are neat, clean, well - groomed and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The County may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Collier County projects is not in the best interest of the County. 23. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of Page -6- 6PII the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish to the Owner the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Owner. 24. PROTECTION OF WORK. A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or anyone for whom Contractor is legally liable is responsible for any loss or damage to the Work, or other work or materials of Owner or Owner's separate contractors, Contractor shall be charged with the same, and any monies necessary to replace such loss or damage shall be deducted from any amounts due Contractor. B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. C. Contractor shall not disturb any benchmark established by the Owner with respect to the Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The Owner shall re- establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 25. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner is obligated to act to prevent threatened damage, injury or loss. Contractor shall give the Owner written notice within forty -eight (48) hours after the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Owner determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty -eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 26. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such designated portion) is substantially complete and request that Owner issue a Certificate of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner does not consider the Work (or designated portion) substantially complete, the Owner shall notify Contractor in writing giving the reasons therefor. If Owner considers the Work (or designated portion) substantially complete, Owner shall prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit D, which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and Page -7- 16RII include a tentative punchlist of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punchlist. Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Owner will make such inspection and, if Owner finds the Work acceptable and fully performed under the Contract Documents, he shall promptly issue a Certificate of Final Completion, Exhibit F, recommending that on the basis of his observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Final payment shall not become due and payable until Contractor submits: (1) The Release and Affidavit in the form attached as Exhibit "B ". (2) Consent of Surety (if applicable) to final payment. (3) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment shall not become due and payable. 27. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to Proceed to be issued by the Owner. Contractor shall commence the work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. The Work shall be substantially completed within the time specified in the Request for Quotation. The date of substantial completion of the Work (or designated portions thereof) is the date certified by the Owner when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. The Work shall reach final completion and be ready for final acceptance by Owner within the time specified in the Request for Quotation. Owner and Contractor recognize that since time is of the essence for any work under this Agreement, Owner will suffer financial loss if the Work is not substantially completed within the time specified in the Request for Quotation. Should Contractor fail to substantially complete the Work within the specified time period, Owner shall be entitled to assess as liquidated damages, but not as a penalty, the amount specified in the Request for Quotation for each calendar day thereafter until substantial completion is achieved. The Project shall be deemed to be substantially completed on the date the Owner issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby 16B11 expressly waives and relinquishes any right which it may have to seek characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to substantially complete the Work in a timely manner. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. 28. CONTRACT ADMINISTRATION. This Agreement shall be administered on behalf of the County by the Transportation Department. 29.COMPONENT PARTS OF THIS CONTRACT. This Contract consists of the attached or referenced component parts, all of which are as fully a part of the Agreement as if herein set out verbatim, including: Contractor's Proposal, Insurance Certificate, ITB 09 -5328, any addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any related plans or specifications for any such Quotations or Work Orders. 30.PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004 -05, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and /or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and /or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and /or quotes; and, c. immediate termination of any contract held by the individual and /or firm for cause. 31. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the parties herein that this Agreement is subject to appropriation by the Board of County Commissioners. 32. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. 33. IMMIGRATION LAW COMPLIANCE: By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 34. VENUE: Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state Page -9- 16P11 courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 35.OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES: Collier County encourages and agrees to the successful proposer extending the pricing, terms and conditions of this solicitation or resultant contract to other governmental entities at the discretion of the successful proposer. 36.AGREEMENT TERMS: If any portion of this Agreement is held to be void, invalid, or otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect. Page -10- IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an autIrIled person or agent, hereunder set their hands and seals on the date and year first above written. ATTEST: Dwight E. Brock, CleZk of Courts ByA Dated: ( 4 C Attest ow to 4^ # BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY. FLORIDA l'. First Witness / Fred W. Coyle, Chairman -' Contractor Better Roads, Inc Signature DiMare Joseph M. Restino rrynt/,Witness Name Typed Signature Dave King V Type /Print Witness Name Appro to form and lega sufficiency Scott ach, Deputy County Attorney Vice President Page -11- Title GP02{��'. SEAL Item # Agenda Date D Date f ! I -in i . EXHIBIT A PUBLIC PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: That Principal, 16B 11 Bond No. Contract No. 09 -5328 as as Surety, located at _ (Business Address) are held and firmly bound to as Oblige in the sum of ($ ) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the 200, with Oblige for day of in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.0592. In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this day of 200, the name of under - signed representative, pursuant to authority of its governing body. Page -12- Signed, sealed and delivered 16 B 1 l in the presence of: PRINCIPAL: Witnesses as to Principal STATE OF _ COUNTY OF By: _ Name: Its: The foregoing instrument was acknowledged before me this of 200_, by , as of a corporation, on behalf of the corporation. He /she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) ATTEST: Witness as to Surety (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: SURETY: (Printed Name) (Business Address) (Authorized Signature) (Printed Name) m Page -13- As Attorney in Fact (Attach Power of Attorney) Witnesses (Business Address) (Printed Name) elephone Number) STATE OF COUNTY OF 16611 The foregoing instrument was acknowledged before me this day of 200_, by as of Surety, on behalf of Surety. He /She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page -14- EXHIBIT A -2 PUBLIC PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and as Surety, located at (Business Address) are held as Oblige in the sum of _ ($ ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. 16B 11 Bond No. Contract No. 09 -5328 and firmly bound to WHEREAS, Principal has entered into a contract dated as of the 200_, with Oblige for day of in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract, and 2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Oblige; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this Performance bond regardless of the number of suits that may be filed by Oblige. Page -15- IN WITNESS WHEREOF, the above parties have executed this instrument this _ 200_, the name of each party being affixed and these presents undersigned representative, pursuant to authority of its governing body. Signed, sealed and delivered in the presence of : Witnesses as to Principal STATE OF _ COUNTY OF PRINCIPAL: By: _ Name: Its: The foregoing instrument was acknowledged before me this 200_, by , as a He /She is personally known to me OR has produced did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) 1611 _ day of duly signed by its day of of corporation, on behalf of the corporation. as identification and (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page -16- ATTEST: SURETY: 16811 Witness as to Surety Witnesses STATE OF COUNTY OF (Printed Name) (Business Address) (Authorized Signature) (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) (Business Address) (Printed Name) (Telephone Number) The foregoing instrument was acknowledged before me this day of 200_, by as of Surety, on behalf of Surety. He /She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) (Signature of Notary) Name: (Legibly Printed) Notary Public, State of _ Commission No.: Page -17- EXHIBIT B RELEASE AND AFFIDAVIT FORM COUNTY OF COLLIER STATE OF FLORIDA ) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ paid, ( "Contractor') releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated 200_ for the period from to (2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, have been fully satisfied and paid. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly /final] Application for Payment No. L]'0 ITS: DATE: Witnesses STATE OF _ COUNTY OF CONTRACTOR The foregoing instrument was acknowledged before me this 200_, by , as ,a personally known to me or has produced _ identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) day of of President [Corporate Seal] corporation, on behalf of the corporation. He /she is as NAME: (Signature of Notary) (Legibly Printed) Notary Public, State of Commissioner No.: Page -18- EXHIBIT C FORM OF CONTRACT APPLICATION FOR PAYMENT (County Project Manager) Bid No. 09 -5328 (County Department) Collier County Board of County Commissioners (the OWNER) or Collier County Water -Sewer District (the OWNER) Project No. Application Date FROM: (Contractor's Representative) Payment Application No. (Contractor's Name) for Work accomplished through the Date: (Contractor's Address) RE: _ Name) Original Contract Time: Revised Contract Time: Retainage @ 10% thru[insert date] Retainage @ _% after [insert date] Percent Work completed to Date: Percent Contract Time completed to Date Liquidated Damages to be Accrued Original Contract Amount: $ Total Change Orders to Date $ Revised Contract Amount $ Total value of Work Completed and stored to Date $ Less previous payment (s) $ AMOUNT DUE THIS APPLICATION: $ ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION s CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive, (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER), (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the revised contract and shall be incorporated into a future Change Order: By CONTRACTOR: DATE: (Contractor's Name) (Signature) (Type Name & Title) be signed by a duly authorized representative of CONTRACTOR) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended: By Design Professional : (DP's Name) (Signature) DATE: (Type Name & Title) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved: By OWNER'S Project Manager: Page -19- (Signature) DATE: _ (Type Name and Title) OWNER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date EXHIBIT D CERTIFICATE OF SUBSTANTIAL COMPLETION ENGINEER'S Project No 16 B II This Certificate of Substantial completion applies to all Work under the Contract documents or to the following specified parts thereof: To C7 UrE :7 And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the contract documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all - inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. Page -20- The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: RESPONSIBILITIES: OWNE CONTRACTO The following documents are attached to and made a part of this Certificate: 168.11 This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20_ Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER 0 Type Name and Title Page -21- 16811 OWNER'S Project No. PROJECT: CONTRACTOR Contract For Contract Date EXHIBIT E CERTIFICATE OF FINAL COMPLETION ENGINEER'S Project No. This Certificate of Final completion applies to all Work under the Contract documents. To CSPA'I.I =1 N And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be finally complete in accordance with the contract documents on: DATE OF FINAL COMPLETION Page -22- The following warranty is attached to and made a part of this Certificate: Executed by Design Professional on EXHIBIT F Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Final Completion on CONTRACTOR Type Name and Title OWNER accepts this Certificate of Final Completion on 0 ovAi/►rfd7 Type Name and Title Page -23- r3M 16811 20_ 20 1681 EXHIBIT G WARRANTY In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the contract either directly performed by the CONTRACTOR or at the express request of the CONTRACTOR by a SUBCONTRACTOR or CONSULTANT. Project Name: Date of Final Completion: Name and Address of CONTRACTOR: CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of all defects of materials and workmanship for a period of one year from the DATE OF FINAL COMPLETION. The undersigned party further agrees that it will, at its own expense, replace and /or repair all defective work and materials and all other work damaged by any defective work upon written demand by the COUNTY. It is further understood that further consideration for this warranty and guaranty is the consideration given for the requirement pursuant to the general conditions and specifications under which the contract was let that such warranty and guaranty would be given. This warranty and guaranty is in addition to any other warranties or guaranties for the work performed under the contract and does not constitute a waiver of any rights provided pursuant to Florida Statutes, Chapter 95, et seq. DATE: CONTRACTOR ly Attest: Page -24- COVERAGES 3 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. IN$R ADD'L POLICY EFFECTIVE POLICY EXPIRATION LIMITS YTR'INSRd TYPE OF INSURANCE POLICY NUMBER oaTE IMMIOOnrrr) DATE IMMIDDIYVYYI GENERAL LIABILITY VTJ EXGL 580OB671 06/01/2009 A 06/01/2010 EACH OCCURRENCE _ 750005! DAMAGE TO RENTED . X COMMERCIAL GENERAL LIABILITY PREMISES(Ee occurrence) I$ 5D0 000' CLAIMS MADE IX IOCCUR 168 11 �' !1 SIR: $250,000 Av D CERTIFICATE DATE OF LIABILITY INSURANCE 04 /15 /MIDDIYYY" 04/15/2010 PRODUCER THIS CERTIFICATION IS ISSUED AS A MATTER OF INFORMATION Marsh ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 3031 N. Rocky Point Drive, Suite 700 HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR Tampa, FL 33607 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Atln: Erica Connick (813) 207 -5100 ALL OMED AUTOS j BODILY INJURY I$ 101266 - Bett- Cas -09 -10 INSURERS AFFORDING COVERAGE NAIC # INSURED - INSURER Travelers Property Casualty Company Of 25674 Better Roads, Inc . 1910 Seward Avenue INSURER B. Everest National Insurance Co 10120 Naples, FL 34109 j OTHER THAN EA ACC '$ INSURER C INSURER B EXCESS I UMBRELLA LIABILITY 71 G 10001117091 06/01/2009 06/0-1/2010 EACH OCCURRENCE I$ 5,000,000 j- INSURER E. _... _.. _— .._._. COVERAGES 3 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. IN$R ADD'L POLICY EFFECTIVE POLICY EXPIRATION LIMITS YTR'INSRd TYPE OF INSURANCE POLICY NUMBER oaTE IMMIOOnrrr) DATE IMMIDDIYVYYI GENERAL LIABILITY VTJ EXGL 580OB671 06/01/2009 A 06/01/2010 EACH OCCURRENCE _ 750005! DAMAGE TO RENTED . X COMMERCIAL GENERAL LIABILITY PREMISES(Ee occurrence) I$ 5D0 000' CLAIMS MADE IX IOCCUR I MED EXP(Any one person) $ !1 SIR: $250,000 PERSONAL & ADV INJURY $ 750,000. I GENERAL AGGREGATE $ 2,000,000 GENERAL AGGREGATE LIMIT APPLIES PER _ — PRODUCTS - CUMPIOP AG $ 2,000,000 X POLICY JECTOC A AUTOMOBILE LIABILITY VTC2J CAP 580OB683 06/01/2009 06/01/2010 COMBINED SINGLE LIMIT _ $ 2,000,000 X l ANY AUTO '. II � F. accident) ALL OMED AUTOS j BODILY INJURY I$ SCHEDULED AUTOS (Per person) FIRED AUTOS BODILY INJURY $ A NON GAINED AUTOS (Per eoodri PROPERTY DAMAGE $ — (Per accident) j!AUTO GARAGE LIABILITY ONLY EA ACCIDENT '$ ANY AUTO j OTHER THAN EA ACC '$ AUTO ONLY.$ GO B EXCESS I UMBRELLA LIABILITY 71 G 10001117091 06/01/2009 06/0-1/2010 EACH OCCURRENCE I$ 5,000,000 X OCCUR CLAIMS MADE AGGREGATE $ 5,000 000 is I DEDUCTIBLE is RETENTION E • WORKERS COMPENSATION AND VTC20 UB 580OB66A 06/01/2009 06/01/2010 X vcc STATU- 10TH - EMPLOYERS'LIABILITY jj �TIIRY LIMAS EH__. ANY PROPRIETORIPARTNERIEXECU71VE Y IN L. EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N -_ -- - - -_- - -- L DISEASE EA EMPLOYEE$ 1,000,000 (MarYM In NH If yes, nescnbe under SPECIALPROVI�IONSbelow -- - -- - FL DISEASE POLICY LIMIT $ 1,000,000 • OTHER Auto Physical Damage IVTJ BAP 58008695 06/01/2009 06/01/2010 Comp /Collision Deductible: j 2004 vehicles or newer: $5,000 20,000 Ids or heavier. $10,000 DESCRIPTION OF OPERATIONSILOCATION SNEHICLESIEXCLUSIONS ADDED BY ENDORSEMENTISPECIAL PROVISIONS Re. Contract #09 -5328 Asphalt, Milling & Related Items. Collier County Board of County Commissioners is included as Additional Insured where required by written contract or agreement with respect to General Liability and Auto Liability. CERTIFICATE HOLDER ATL- 002127173 -01 CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE Collier County Board of EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL County Commissioners 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, 3301 E. Tamiami Trail Naples, FL 34112 BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES, pqE Aor Ma M6 rBIRPIpCSENTATIVE Erica Connick ACORD 25 (2009/01) ©1998 -2009 ACORD CORPORATION. All Rights Reserved The ACORD name and logo are registered marks of ACORD 16B 11 IMPORTANT If the certificate holder is an ADDITIONAL INSURED. the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). 116Y�1�1h'il�:? This Certificate of Insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ITEM NO.: lo-i�, - C)l�0 Lps- FILE NO.: ROUTED TO: DO NOT WRITE ABOVE THIS LINE 16811 DATE RECEIVED: J VAIA REQUEST FOR LEGAL SERVIC Date: July 19, 2010 To: County Attorney's Office Jeff Klatzkow, County Attorney From: Brenda Brilhart, Purchasing Agent Purchasing Department, Extension 8446 Re: Contract: #09 -5328 "Asphalt, Milling 51ZT / Related Items" Contractor: C.W. Roberts Contracti g, Inc. (Cougar Division) BACKGROUND OF REQUEST: This Contract was approved by a BCC on April 13, 2010, i Agenda Item 16.B.11 This item has not been previo ACTION REQUESTED: Contract review and approval. OTHER COMMENTS: This is a standard contract wit BCC for signature after approval. If the document, please contact me. Purchasing the documents exit your office. Thank you. C: Alex Blanco, Road & Bridge submitted. no changes. Please forward to the are any questions concerning the would appreciate notification when ran 5KJ�3� bVj- �- 4-6 �l�v 16811 ` STATE CERTIFIED GEN. CONTRACTOR CGC 062016 CONTRACTING - DIVISION OF C.W. ROBERTS CONTRACTING, INC. 13350 RICK ENBACKER PKWY. FORT MYERS, FLORIDA 33913 (239) 225-0565 FAX: (239) 225-0564 September 1, 2010 Administrative Services Division Purchasing Department 3301 Tamiami Trail East Naples, Florida 34112 RE: Collier County Annual Contract - #9 -5328 To whom it may concern: We the undersigned, hereby authorize Tim Hurley, Vice President of C.W. Roberts Contracting, Inc., to act on our behalf in all manners relating to the above referenced project, including signing of all documents relating to these matters. This authorization is valid until further written notice from C.W. Roberts Contracting, Inc. Sincerely, C.W. Roberts Contracting, Inc. Charles W. Roberts President The foregoing instrument was acknowledged before me this 1" day of September, 2010, by Charles W. Roberts, who is personally known to me. Q&a"n 00 i4� . RZENE COLLINS UI'VIh ISSIOV # DD8 80173 EXPIRES May 07, 2013 16B11 MEMORANDUM TO: Ray Carter Risk Management Department FROM: Brenda Brilhart, Purchasing Agent Purchasing Department DATE: July 19, 2010 RE: Review of Insurance for Contract: #09 -5328 "Asphalt, Milling & Related Items" Contractor: C.W. Roberts Contracting, Inc. (Cougar Division) This Contract was approved by the BCC on April 13, 2010, Agenda Item 16.13.11 Please review the Insurance Certificates for the above referenced contract. If you have any questions, please contact me at extension 8446. Thank you. ,7F (7K � ON ,L Con A. DATE RECEIVED JUL 2 0 2010 dod /BB RISK MANAGEMENT C: Alex Blanco, Road & Bridge ?IVI s PeCerdS I"I <aSe v-,e-4tAF,j q CoP� IL mausen_g 16811 From: RaymondCarter Sent: Thursday, July 22, 2010 11:01 AM To: BrilhartBrenda Cc: DeLeonDiana; mausen _g; HerreraSandra; BlancoAlexander Subject: Contract 09 -5328 "Asphalt, Milling & Related Items" All, I have approved the certificate of insurance provided by C.W. Roberts contracting, Inc. (Cougar Division) for contract 09 -5328. The contract will now be forwarded to the county attorney's office for their review. Thank you, Ray Manager Risk Finance Office 239 - 252 -8839 Cell 239 - 821 -9370 Under Florida Law, e-mail addresses are public records. If you do not want your e-mail address released in response to a public records request, do not send electronic mail to this entity. Instead, contact this office by telephone or in writing. RLS # l�S_C� 8 CHECKLIST FOR REVIEWING CONTRACTS Entity Name: f 16 B 11 Entity name correct on contract? i No �Ye En tity registered with FL Sec. of State? !s No Insurance Insurance Certificate attached? es Insured registered in Florida? Yes Contract # &/or Project referenced on Certificate? � P►' ,Yes Certificate Holder name correct (BCC)? ,, Yes Commercial General Liability General Aggregate Req d $ Provided $ Z Yh Products/Compl/Op e $ Provided Personal & Advert(,/P" qu ed $ rJ' Provided Each Occurrence \trRequired $ \ Provided $ t t Fire/Prop Damage Required $ Provided $� Automobile Liability Bodily Inj & Prop Required $ '2IYl t k Workers Compensation Provided $ l` e �..� ZtS , Each accident Required l $ ovi ed $ Disease Aggregate Required $ Provided Disease Each Empl Required $ Provided W� Umbrella Liability Each Occurrence Provided $ C,::� M r Aggregate Provided $yam �� Does Umbrella sufficiently cover any underinsured portion? Professional Liability Each Occurrence Required $ Provided $ Per Aggregate Required $ Provided $ Other Insurance Each Occur Type: Required $ Countyrequired to be named as additional insured? County named as additional insured? Indemnification Does indemnification meet County standards? Is County indemnifying other party? Performance Bond Bond requirement referenced in contract? If attached, expiration date of bond Does dollar amount match contract? Agent registered in Florida? Signature Blocks Correct executor name in signature block? Correct title of executor? Executor authorized to sign for entity? Proper number of witnesses/notary? Authorization for executor to sign, if necessary: Chairman's signature block? Clerk's attestation signature block? County Attorney's signature block? Attachments Are all required attachments included? No No No No Exp. Date 6 1 Q Exp. Date Exp. Date t C Exp. Date Exp. Date Exp Date Exp Date I ( D Exp Date Exp Date Exp Date D Exp, Date / �� 'es No Exp. Date Exp. Date Provided $ l /Yes Yes Yes Yes _k�yes Yes Yes `s es Yes V y es es Yes Exp Date No No No 0 No , -Ay', p(01 IJ r� No No No No No No No No No No Reviewer Initials: Date: I 04 -COA -010 / 22 16011 .ROB�,�� 1CON1RAmmo, u r www.cwrcontracting.com CORPORATE OFFICE 3372 Copilot Circle NE Tollohossee, FL 32308 (850) 3853060 Phone (850) 3855420 fox HOSFORD OFFICE P.O. Box 188 Hosford, ft 32334 (850) 3798116 Phone (850) 3798188 fox FREEPORT OFFICE 160 Industrial Pork Rood Freeport, fL 32439 (850) 835.3500 Phone 1850) 8353519 Fox WILDINOOD OFFICE 4208 Count' Rood 124-A Wildwood, FL 34785 (352) 330.2540 Phone (352) 330.2609 Fox PANAMA CITY OFFICE 1603 Boy Avenue Ponomo Clr, Ft 32405 (850) 7696640 Phone (850) 769.7775 Fox FORT MYERS OFFICE 13350 Rkkenbocker Porkwoy Foil Myers, R 33913 (239) 225 -0565 Phone (239) 225.0564 fox July 12, 2010 Administrative Services Division Purchasing Department 3301 Tamiami Trail East Naples, Florida 34112 RE: Collier Co. Annual Contract # 09 -5328 To whom it may concern: We the undersigned, hereby authorize Tim Hurley, Vice President of C.W. Roberts Contracting, Inc., to act on our behalf in all manners relating to the above referenced project, including signing of all documents relating to these matters. This authorization is valid until further written notice from C. W. Roberts Contracting, Inc. Sincerely, C. Wo /erts Co trading, Inc. Z - Y� Charles W. Roberts President www.sunbiz.org - Department of State Home Contact Us E- Filing Services Previous on List Next on List Return To List Events No Name History Detail by Entity Name Florida Profit Corporation C. W. ROBERTS CONTRACTING, INCORPORATED Filing Information Document Number 493846 FEI/EIN Number 591683951 Date Filed 01/19/1976 State FL Status ACTIVE Last Event MERGER Event Date Filed 01/30/2002 Event Effective Date NONE Principal Address 3372 CAPITAL CIRCLE NE TALLAHASSEE FL 32308 Changed 04 /09/2007 Mailing Address P.O. BOX 16279 TALLAHASSEE FL 32317 Changed 04 /09/2007 Registered Agent Name & Address ROBERTS, CHARLES W, III 15674 HALES PLACE PLANTATION ROAD TALLAHASSE FL 32312 US Address Changed: 02/03/1997 Officer /Director Detail Name & Address Title PD ROBERTS, CHARLES W., III 15674 HALES PLACE PLANTATION ROAD TALLAHASSEE FL 32312 Title VP ROBERTS, GEORGE A. 3510 FOXRUN BLVD PANAMA CITY FL 32408 Title S Document Searches 16'911 Forms Help Entity Name Search Submit http: / /www. sunbiz.org/ scripts /cordet.exe? action = DETFIL &inq_doc_number =493 846 &inq... 4/13/2010 16811 AGREE MEN T09 -5328 for Asphalt, Milling & Related Items THIS AGREEMENT is made and entered into this 13th day of April 2010, by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "County" or "Owner") and C. W. Roberts Contracting, Inc. (Cougar Division), authorized to do business in the State of Florida, whose business address is 13350 Rickenbacker Parkway, Fort Myers, Florida 33913 (hereinafter referred to as the "Contractor"). WITNESSETH: 1. COMMENCEMENT: The contract shall be for a one (1) year period, commencing on April 13, 2010, and terminating April 12, 2011, or until such time as all outstanding Purchase Orders issued prior to the expiration of the Agreement period have been completed. This contract shall have three one (1) year renewals, renewable annually. The County Manager, or his designee, may, at his discretion, extend the Agreement under all of the terms and conditions contained in this Agreement for up to one hundred eighty (180) days. The County Manager, or his designee, shall give the Contractor written notice of the County's intention to extend the Agreement term not less than ten (10) days prior to the end of the Agreement term then in effect. 2. STATEMENT OF WORK: The Board of County Commissioners deemed two (2) firms to be pre - qualified and awarded a Contract to each firm on a Primary/Secondary basis. Each awardee will enter into an Agreement to provide complete services for asphalt, milling and related services on an as- needed basis as may be required by the Owner in accordance with the terms and conditions of ITB 09 -5328 and the Contractor's proposal, which is incorporated by reference and made an integral part of this Agreement. The execution of this Agreement shall not be a commitment to the Contractor that any work will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the Quotation procedure outlined in the next paragraphs and all Work undertaken by Contractor for Owner pursuant to this Agreement and that procedure during the term and any extension of the term of this Agreement. For non - emergency work, the Owner shall provide a summary of Work to be performed which will afford the Contractor the opportunity to submit a formal quotation for the new work. The work shall consist of one or more individual work assignments, or groupings of work assignments. The Contractor shall respond with the information sought within seven (7) working days. A purchase order for the quoted work will be awarded to the primary Contractor if that Contractor is able to complete the non - emergency work in the timeframe and within the budget required by the County. If the primary contractor cannot meet the required timeframe and /or budget, a quote will be obtained from the secondary Contractor. In each Request for Quotation, the Owner reserves the right to specify the period of completion and the collection of liquidated damages in the event of late completion. 3. THE CONTRACT SUM: The Owner shall pay the Contractor for the performance of the Work pursuant to the quoted price based on unit prices offered by the Contractor at time of bid. Any Page -1- 16811 County agency may utilize the services offered under this contract, provided sufficient funds are included in its budget(s). 4. NOTICES: All notices required or made pursuant to this Agreement to be given by the County to the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following Contractor's address of record: Tim Hurley, Vice President C. W. Roberts Contracting, Inc. (Cougar Division) 13350 Rickenbacker Parkway Fort Myers, Florida 33913 Phone: (239) 225 -0565 Fax: (239) 225 -0564 All notices required or made pursuant to this Agreement to be given by the Contractor to the County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following County's address of record: Collier County Government Complex Purchasing Department 3301 East Tamiami Trail Purchasing Building G Naples, Florida 34112 Attention: Stephen Y. Carnell Purchasing /General Services Director Phone: 239 - 252 -8371 Fax: 239 - 252 -6584 The Contractor and the County may change the above mailing address at any time upon giving the other party written notification. All notices under this Service Agreement must be in writing. 5. NO PARTNERSHIP: Nothing herein contained shall create or be construed as creating a partnership between the County and the Contractor or to constitute the Contractor as an agent of the County. 6. PERMITS: LICENSES: TAXES: In compliance with Section 218.80, Florida Statutes, all permits necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all such permits issued by the County shall be processed internally by the County. Contractor is not responsible for paying for permits issued by Collier County, but is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier county agencies when the Contractor is acquiring permits. All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. Page -2- 16811 7. NO IMPROPER USE: The Contractor will not use, nor suffer or permit any person to use in any manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation, or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the event of such violation by the Contractor or if the County or its authorized representative shall deem any conduct on the part of the Contractor to be objectionable or improper, the County shall have the right to suspend the Contract of the Contractor. Should the Contractor fail to correct any such violation, conduct, or practice to the satisfaction of the County within twenty -four (24) hours after receiving notice of such violation, conduct, or practice, such suspension to continue until the violation is cured. The Contractor further agrees not to commence operation during the suspension period until the violation has been corrected to the satisfaction of the County. 8. TERMINATION: Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County and requirements of this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a seven (7) day written notice. The County shall be sole judge of non - performance. 9. NO DISCRIMINATION: The Contractor agrees that there shall be no discrimination as to race, sex, color, creed or national origin. 10. INSURANCE: The Contractor shall provide insurance as follows: A. Commercial General Liability: Coverage shall have minimum limits of $5,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent contractors; Products and Completed Operations and Contractual Liability. B. Business Auto Liability: Coverage shall have minimum limits of $2,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall include Owned Vehicles, Hired and Non -Owned Vehicles and Employee Non - Ownership. C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in compliance with the applicable state and federal laws. The coverage must include Employers' Liability with a minimum limit of $1,000,000 for each accident. Special Requirements: Collier County Board of County Commissioners shall be listed as the Certificate Holder and included as an Additional Insured on the Comprehensive General Liability. Current, valid insurance policies meeting the requirement herein identified shall be maintained by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification to the County in the event of cancellation or modification of any stipulated insurance coverage. Contractor shall insure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Contractor shall provide County with certificates of insurance meeting the required insurance provisions. Page -3- 16811 11. INDEMNIFICATION: To the maximum extent permitted by Florida law, the ContractorNendor / Consultant shall indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the ContractorNendor /Consultant or anyone employed or utilized by the ContractorNendor /Consultant in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 12. BONDS. A. When a construction project is in excess of $200,000, the Contractor(s) shall be required to provide Payment and Performance Bonds. B. When required by Owner, the Contractor shall furnish a Performance and /or Payment Bond prior to commencing performance, for the full amount of the Work, which shall act as a security guaranteeing the performance of the Contractor's work and the payment by the Contractor to any other party (ies) providing labor and /or materials in connection with each construction or renovation project performed by the Contractor. The bonds shall be furnished using the forms prescribed in Exhibit "A ". C. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute another bond and surety, both of which shall be subject to the Owner's approval. 13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in excess of thirty (30) days, the Contractor may indicate on his response to the Request for Quotation the wish to receive Progress Payments. Subsequent to the first payment, Contractor must provide Owner with a fully executed Release and Affidavit in the form attached hereto as Exhibit "B" as a condition precedent to release of each progress payment. All applications for payment, whether for full payment or a progress payment shall be in writing, and in substantially the form attached hereto as Exhibit "C ". 14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or portions thereof, because of defective or incomplete work, outstanding punch list items, subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence indicating probable fling of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents. Page -4- 16811 If any conditions described above are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products /materials from specifications shall be approved in writing by Owner in advance. 16. CONTRACT TIME AND TIME EXTENSIONS. A. Time is of the essence in the performance of any Work under this Agreement and Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and materialmen, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's supplies and contractors. B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty -eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. C. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any modifications to this Contract shall be in compliance with the County Purchasing Policy and Administrative Procedures in effect at the time such modifications are authorized. Page -5- 16811 18. COMPLIANCE WITH LAWS. Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, workers' compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Owner in writing. 19. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 20. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 21. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any materialmen supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specked, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after final completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 22. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on County projects who are neat, clean, well - groomed and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The County may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Collier County projects is not in the best interest of the County. 23. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of Page -6- 16811 the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish to the Owner the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Owner. 24. PROTECTION OF WORK. A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or anyone for whom Contractor is legally liable is responsible for any loss or damage to the Work, or other work or materials of Owner or Owner's separate contractors, Contractor shall be charged with the same, and any monies necessary to replace such loss or damage shall be deducted from any amounts due Contractor. B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. C. Contractor shall not disturb any benchmark established by the Owner with respect to the Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The Owner shall re- establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 25. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner is obligated to act to prevent threatened damage, injury or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Owner determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty -eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 26. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such designated portion) is substantially complete and request that Owner issue a Certificate of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall make an inspection of the Work (or designated portion thereof) to determine the status of completion. If Owner does not consider the Work (or designated portion) substantially complete, the Owner shall notify Contractor in writing giving the reasons therefore. If Owner considers the Work (or designated portion) substantially complete, Owner shall prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit D, which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and Page -7- 16811 include a tentative punch list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch list. Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Owner will make such inspection and, if Owner finds the Work acceptable and fully performed under the Contract Documents, he shall promptly issue a Certificate of Final Completion, Exhibit F, recommending that on the basis of his observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Final payment shall not become due and payable until Contractor submits: (1) The Release and Affidavit in the form attached as Exhibit "B ". (2) Consent of Surety (if applicable) to final payment. (3) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment shall not become due and payable. 27. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to Proceed to be issued by the Owner. Contractor shall commence the work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. The Work shall be substantially completed within the time specified in the Request for Quotation. The date of substantial completion of the Work (or designated portions thereof) is the date certified by the Owner when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. The Work shall reach final completion and be ready for final acceptance by Owner within the time specified in the Request for Quotation. Owner and Contractor recognize that since time is of the essence for any work under this Agreement, Owner will suffer financial loss if the Work is not substantially completed within the time specked in the Request for Quotation. Should Contractor fail to substantially complete the Work within the specified time period, Owner shall be entitled to assess as liquidated damages, but not as a penalty, the amount specified in the Request for Quotation for each calendar day thereafter until substantial completion is achieved. The Project shall be deemed to be substantially completed on the date the Owner issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby Page -8- 16811 expressly waives and relinquishes any right which it may have to seek characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to substantially complete the Work in a timely manner. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. 28. CONTRACT ADMINISTRATION. This Agreement shall be administered on behalf of the County by the Transportation Department. 29. COMPONENT PARTS OF THIS CONTRACT. This Contract consists of the attached or referenced component parts, all of which are as fully a part of the Agreement as if herein set out verbatim, including: Contractor's Proposal, Insurance Certificate, ITB 09 -5328, any addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any related plans or specifications for any such Quotations or Work Orders. 30. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004 -05, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and /or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and /or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and /or quotes; and, c. immediate termination of any contract held by the individual and /or firm for cause. 31. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the parties herein that this Agreement is subject to appropriation by the Board of County Commissioners. 32. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. 33. IMMIGRATION LAW COMPLIANCE: By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 34. VENUE: Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state Page -9- 16611 courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 35. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES: Collier County encourages and agrees to the successful proposer extending the pricing, terms and conditions of this solicitation or resultant contract to other governmental entities at the discretion of the successful proposer. 36. AGREEMENT TERMS: If any portion of this Agreement is held to be void, invalid, or otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect. Page -10- 16811 IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an authorized person or agent, hereunder set their hands and seals on the date and year first above written. ATTEST: Dwight E.ock, CIeK cf. Courts . -. ' I -I 7,1'Il��1'I�J� �H-Ilr 1117 o._IS 9 n1jf y'\ Type /Print Witness Name Second Witness S- &OC Cool Iir5 Type /Print Witness Name lega to forrr(a 1q .G4a County Attorney BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA B Y � W• Fred W. Coyle, ChairmanP Contractor C. W. Roberts Contracting, Inc. (Cougar Division) By: SignaVfe A rlz., Typed Signature y, -cv ) �rf,' t Title Page -11- 16811 EXHIBIT A PUBLIC PAYMENT BOND Bond No. Contract No. 09 -5328 KNOW ALL MEN BY THESE PRESENTS: That as Principal, and , as Surety, located at (Business Address) are held and firmly bound to as Oblige in the sum of ($ ) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the , 200_, with Oblige for day of in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.0592. In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this day of 200_, the name of under - signed representative, pursuant to authority of its governing body. Page -12- Signed, sealed and delivered in the presence of: Witnesses as to Principal STATE OF _ COUNTY OF PRINCIPAL: By: _ Name: Its: 16811 The foregoing instrument was acknowledged before me this of 200_, by as of a corporation, on behalf of the corporation. He /she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) ATTEST: Witness as to Surety (Signature of Notary) Name: (Legibly Printed) Notary Public, State of _ Commission No.: SURETY: (Printed Name) (Business Address) (Authorized Signature) (Printed Name) M Page -13- Witnesses STATE OF _ COUNTY OF As Attorney in Fact (Attach Power of Attorney) (Business Address) (Printed Name) (Telephone Number) 16811 The foregoing instrument was acknowledged before me this day of 200_, by , as Of , Surety, on behalf of Surety. He /She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page -14- EXHIBIT A -2 PUBLIC PERFORMANCE BOND 16811 Bond No. Contract No. 09 -5328 KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and as Surety, located at (Business Address) are held and firmly bound to as Oblige in the sum of ($ ) for the payment whereof we bond executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the 200_, with Oblige for day of ourselves, our heirs, in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat hereof, and is referred to as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract, and 2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Oblige; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or to work or to the specifications. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this Performance bond regardless of the number of suits that may be filed by Oblige. Page -15- 16811 IN WITNESS WHEREOF, the above parties have executed this instrument this day of 200_, the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. Signed, sealed and delivered in the presence of : Witnesses as to Principal STATE OF _ COUNTY OF PRINCIPAL: By: _ Name: Its: The foregoing instrument was acknowledged before me this 200_, by , as ,a He /She is personally known to me OR has produced did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) day of of corporation, on behalf of the corporation. as identification and (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page -16- ATTEST: Witness as to Surety Witnesses STATE OF _ COUNTY OF SURETY: (Printed Name) (Business Address) (Authorized Signature) (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) (Business Address) (Printed Name) (Telephone Number) 16811 The foregoing instrument was acknowledged before me this day of 200_, by , as of , Surety, on behalf of Surety. He /She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) (Signature of Notary) Name: (Legibly Printed) Notary Public, State of Commission No.: Page -17- 16811 EXHIBIT B RELEASE AND AFFIDAVIT FORM COUNTY OF COLLIER STATE OF FLORIDA ) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ paid, ( "Contractor") releases and waives for itself and it's subcontractors, material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated , 200 for the period from to (2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, have been fully satisfied and paid. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly /final] Application for Payment No. AN ITS: DATE: Witnesses STATE OF _ COUNTY OF CONTRACTOR President [Corporate Seal] The foregoing instrument was acknowledged before me this day of , 200_, by , as of a corporation, on behalf of the corporation. He /she is personally known to me or has produced as identification and did (did not) take an oath. My Commission Expires: (AFFIX OFFICIAL SEAL) NAME: (Signature of Notary) (Legibly Printed) Notary Public, State of Commissioner No.: Page -18- EXHIBIT C 16811 FORM OF CONTRACT APPLICATION FOR PAYMENT (County Project Manager) Bid No. 09 -5328 (County Department) Collier County Board of County Commissioners (the OWNER) or Collier County Water -Sewer District (the OWNER) FROM: (Contractor's Representative) (Contractor's Name) (Contractor's Address) RE: _ Name) Original Contract Time: Revised Contract Time: Retainage @110% thru [insert date] $ Retainage @ _% after [insert date] $ Percent Work completed to Date: Percent Contract Time completed to Date % Liquidated Damages to be Accrued $, Project No. Application Date Payment Application No. for Work accomplished through the Date: Original Contract Amount: $ Total Change Orders to Date $ Revised Contract Amount $ Total value of Work Completed and stored to Date $ Less previous payment (s) $ AMOUNT DUE THIS APPLICATION: $ Project ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances (except such as covered by Bond acceptable to OWNER); (3) all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the revised contract and shall be incorporated into a future Change Order: By CONTRACTOR: DATE: (Contractor's Name) (Signature) (Type Name & Title) (shall be signed by a duly authorized representative of CONTRACTOR) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended: By Design Professional: (DP's Name) (Signature) DATE: (Type Name & Title) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved: By OWNER'S Project Manager: Page -19- (Signature) DATE: _ (Type Name and Title) OWNER'S Project No. PROJECT: CONTRACTOR Contract For _ Contract Date EXHIBIT D CERTIFICATE OF SUBSTANTIAL COMPLETION ENGINEER'S Project No. 16811 This Certificate of Substantial completion applies to all Work under the Contract documents or to the following specified parts thereof: To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the contract documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all - inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. Page -20- 16811 The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: RESPONSIBILITIES: OWNER: CONTRACTOR: The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20_ Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on , 20_ CONTRACTOR Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20_ OWNER Type Name and Title Page -21- 16811 OWNER'S Project No. PROJECT: CONTRACTOR Contract For _ Contract Date EXHIBIT E CERTIFICATE OF FINAL COMPLETION ENGINEER'S Project No. This Certificate of Final completion applies to all Work under the Contract documents. To OWNER And To The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be finally complete in accordance with the contract documents on: DATE OF FINAL COMPLETION Page -22- The following warranty is attached to and made a part of this Certificate: Executed by Design Professional on EXHIBIT F Design Professional 20 16811 By: Type Name and Title CONTRACTOR accepts this Certificate of Final Completion on , 20_ CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Final Completion on , 20_ OWNER By: Type Name and Title Page -23- 16811 EXHIBIT G WARRANTY In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the contract either directly performed by the CONTRACTOR or at the express request of the CONTRACTOR by a SUBCONTRACTOR or CONSULTANT. Project Name: Date of Final Completion: Name and Address of CONTRACTOR: CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of all defects of materials and workmanship for a period of one year from the DATE OF FINAL COMPLETION. The undersigned party further agrees that it will, at its own expense, replace and /or repair all defective work and materials and all other work damaged by any defective work upon written demand by the COUNTY. It is further understood that further consideration for this warranty and guaranty is the consideration given for the requirement pursuant to the general conditions and specifications under which the contract was let that such warranty and guaranty would be given. This warranty and guaranty is in addition to any other warranties or guaranties for the work performed under the contract and does not constitute a waiver of any rights provided pursuant to Florida Statutes, Chapter 95, et seq. DATE: CONTRACTOR BY: Attest: Page -24- 16811 A%ORD� CERTIFICATE OF INSURANCE ISSUE DATE 06118=10 PRODUCER MCGRIFF, SEIBELS WILLIAMS, INC. P.O. Box 10265 Birmingham, AL 35202 800 -476 -2211 This certificate Is issued as a matter of information only and confers no nights upon the Certificate Holder. This Certificate does not amend, extend or attar the coverage afforded by the policies below. COMPANIES AFFORDING COVERAGE Company Travelers indemnity Company INSURED C.W. Roberts Contracting, Inc. P.O. Box 188 Hostord, FL 32334 company Travelers Prop. Casualty Co. of America Company Charter Oak Fire Insurance Company Company Navigators insurance Company Company E This Is to certify that the policies of insurance described herein have been Issued to the Insured named herein for the policy period indicated. Notwithstanding any requirement, term or condition of contract or other document with respect to which this certificate may be Issued or may pertain, the insurance afforded by the policies described herein is subject to all the terms, conditions and exclusions of such policies. Limits shown may have been reduced by paid claims. CO LT TYPE OF INSURANCE POLICY NUMBER EFFECTIVE EXPIRATION LIMITS OF LIABILITY A GENERAL LIABILITY ®Comm 21GMWUat>;Hy ❑CidrmMade ®Oocumncs ❑ owrwe and contodors Protection ❑ GeneralA �°towritaw- par. ❑ P." 131 t'roJed ❑ L.-M. VTC2KCO1098A434 09/30/2009 09/30/2010 EACH OCCURRENCE $ 1,000,000 FIRE DAMAGE $ 300,000 MEDICAL EXPENSE $ 5,000 PERS. AND ADVERTISING INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 PRODUCTS AND COMP.OPER.AGG. S 2,000,000 B AUTOMOBILE LIABILITY mi Arty hkomme ❑ Al OenedAutarabies ❑ scn.auad Aubmobies 0HkWAut«rnbbs ® NwHmned AtAars WW ® Eseass Awwwwe-sl,000,000 CSL VTC2JCAP5786B95A AR6460150 - Colony National Insurance Company 09/30/2009 0913012010 COMBINED SINGLE LIMIT $ 1,000,000 g DILY INJURY Per on $ BODILY INJURY Per accident) S PROPERTY DAMAGE (Per accidentl $ COMPREHENSIVE COLLISION C WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY VFC20UB4529BB33 09/30/2009 09130/2010 % t tut l i X I Other EL EACH ACCIDENT $ 1,000,000 EL DISEASE E $ 1,000,000 EL DISEASE (Policy Limit $ 1,000,000 D EXCESS LIABILITY ® Oaunanoa ❑Gams Made SF09EXCO94572NV 09/30/2009 09/30/2010 EACH OCCURRENCE $ 5,000,000 AGGREGATE S 5,000,000 3 S S S S Certificate Holder is Additional insured under General Liability as required by written contract subject to policy terms, conditions, and exclusions. CERTIFICATE HOLDER Collier County Board of County Commissioners Purchasing Department 3301 Tamiami Trail East Naples, FL 34112 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT; BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES. Authorized Representative _ - 41 page 1 of 1 Certierate104 6E8KTVYB