Agenda 06/25/2013 Item #16D 7n
6/25/2013 16.D.7.
EXECUTIVE SUMMARY
Recommendation to award ITB #13 -6032 in the amount of $49,560 to FA Remodeling and Repairs,
for cleaning and painting of the Roller Hockey Rink at Veterans Community Park and authorize
the Board's Chairwoman to approve the attached County Attorney reviewed contract.
Obiective: To preserve, clean and maintain the structural steel of the Roller Hockey Rink.
Considerations: On April 9, 2013, the Purchasing Department posted ITB #13 -6032 for painting the
Roller Hockey Rink.
The Invitation to Bid included the supply of all materials, labor and equipments necessary to clean and
paint the structural steel and concrete piers of the Veterans Park Roller Hockey Rink. The cleaning will
include high pressure washing and mechanical power tools on structural steel and concrete piers. Low
pressure washing will be done for the ceilings. After' cleaning, approved painting will be done on all
structural steel and concrete piers.
Notices were sent electronically to 464 registered bidders, 48 bidders downloaded the bid documents, and
7 bid submissions were received on May 2, 2013. The tabulation of bids is attached. The seven bidders
are:
Total Proiect Cost
FA Remodeling and Repairs $ 49,560
Harry's Painting $ 61,462
Marzuccos Construction $ 65,038
Total Painting $ 70,543
CSJ of SWL $115,644
FL Painters $137,455
Staff reviewed the bid responses and recommends awarding the bid to FA Remodeling and Repairs, Inc.
who provided the lowest combined project cost based on the 60-day period for project completion (Base
Bid A and Alternative 1).
Fiscal Imnact: Funds are budgeted in Veterans Park Rink 80217 in the Parks and Recreation Capital
Fund 306. Source of funding is a transfer from both the General Fund 001 and MSTD Unincorporated
General Fund 111.
Legal Considerations: This item has been approved as to form and legality and requires a majority vote
for approval. - ERP
Growth Management Imnact: none
Recommendation: That the Board of County Commissioners awards Bid #13 -6032 to FA Remodeling
and Repairs, in the sum of $49,560 and authorize the Board's Chairwoman to approve the attached
County Attorney reviewed contract.
Prepared by: Vicky Ahmad, Project Manager, Facilities Management Department
Packet Page -888-
6/25/2013 16.D.7.
COLLIER COUNTY
Board of County Commissioners
Item Number: 16.16.D.16.D.7.
Item Summary: Recommendation to award ITB #13 -6032 in the amount of $49,560 to FA
Remodeling and Repairs, for cleaning and painting of the Roller Hockey Rink at Veterans
Community Park and authorize the Board's Chairwoman to approve the attached County
Attorney reviewed contract.
Meeting Date: 6/25/2013
Prepared By
Name: BetancurNatali
Title: Operations Analys, Parks & Rec -NCRP Admin
5/30/2013 1:59:35 PM
Submitted by
Title: Project Manager,Parks & Recreation
Name: AhmadVicky
5/30/2013 1:59:36 PM
Approved By
Name: WilliamsBarry
Title: Director - Parks & Recreation,Parks & Recreation
Date: 5/30/2013 3:55:56 PM
Name: JonesHank
Title: Project Manager, Principal,Facilities Management
Date: 5/30/2013 4:45:48 PM
Name: WardKelsey
Title: Manager - Contracts Administration,Purchasing & Ge
Date: 5/31/2013 11:34:03 AM
Name: NorthrupAdam
Title: Procurement Strategist, Purchasing
Date: 6/4/2013 8:12:12 AM
Packet Page -889-
6/25/2013 16.D.7.
Name: AlonsoHailey
Title: Operations Analyst, Public Service Division
Date: 6/4/2013 9:44:58 AM
Name: MarkiewiczJoanne
Title: Manager - Purchasing Acquisition,Purchasing & Gene
Date: 6/4/2013 12:55:26 PM
Name: PepinEmily
Title: Assistant County Attorney, CAO Litigation
Date: 6/11/2013 3:08:33 PM
Name: CarnellSteve
Title: Director - Purchasing /General Services,Purchasing
Date: 6/11/2013 4:27:19 PM
Name: KlatzkowJeff
Title: County Attorney
Date: 6/1.4/2013 8:02:22 AM
Name: UsherSusan
Title: Management/Budget Analyst, Senior,Office of Manage
Date: 6/18/2013 11:24:57 AM
Name: IsacksonMark
Title: Director -Corp Financial and Mgmt Svs,CMO
Date: 6/18/2013 12:02:53 PM
Packet Page -890-
d 00 r-
lD d
cu o
Ln
'Ln
o 'E
c
0 3 �
++ O N
m p
U
0
z
Y
C_
a�
Y
v
O
L
O
Y
m
c a
r_
m
C!
4J
m 'm
a
c
m
C
fp
GJ
U
N
M
O
t0
M
V-4
O_
E "
L
Q L
i O
Y Z
V E
m
4J Q
to ,
ro +�
C C
m N
_s E
v
u
U
O O
d d
to
O
0
O
p
c
o
co
°
m
c
r'
O
LLn
O
m
_
r,
z
o)
z
00
'ji
�.o
0
i
00
00
°o
°o
0
0
LM
o
LM
O
m
J'
M
O
r1
N
N
V
4A.
i!?
to
O
O
O
O
O
O
C
�
d
d
-q
n
Lr
Sri
Lri
Lri
Ln
Lr)
L
m
_
v f
in
00
00
O
O
c
n
n
M
W
00
NO
L,
Lri
Ili
d
Ln
N
N
m
'O
:
rM-{
�
0
LL
O
OO
O
O
O
�
O
O
N
0
C
m
o
E
v
ro
Itt
o`
LL
tr?
N
rn
'.
m
M
'.
00
(N
.
00
00
u
O
00
N
N
N
N
3
^
C')
i
r-I
tD
M
M
fC
lD
lD
c
0
,L
U
G7
0
Q
m
LLf
(V
'a
-0
p
Q
N
co
m
m
Z
co
0
at
C
C
LA
mm
Io
mJ
m
<<
Q
'L'0'9 � UOZ /9Z/9
-169- @Sed I@PEd
d
O
O
M
M
r-I
O
N
N
O
V1
O
Q
t
L
O
z
E
ra
Q
N
rC
\
v
C
N
Q
u
Im
C.)-
O
O
M
m
r-i
O
N
N
O
\
u1
O
ro
N
C)
CC
ro
C
N
m
f6
\
V)
N
C
41
O
6/25/2013 16.D.7.
A G R E E M E N T 13-6032
for
THIS AGREEMENT is made and entered into this day of , 2013, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner ") and FA Remodeling and Repairs,
Inc., authorized to do business in the State of Florida, whose business address is 8244 Key Royal
Circle, #636, Naples, FL 34119 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. COMMENCEMENT: The contract shall be for a sixty -one (61) day period, commencing on August
5, 2013 and terminating on October 5, 2013.
2. STATEMENT OF WORK: This Agreement is to award Work in accordance with the terms and
conditions of ITB #13 -6032 — Cleaning and Painting of Structural Steel and Concrete Piers at
Veterans Park Roller Hockey Rink and the Contractor's proposal, which is incorporated by
reference and made an integral part of this Agreement. The Work will include Base Bid Option A
— Cleaning and Painting of Structural Steel with sixty (60) day completion time, and Alternate Bid 1
— Cleaning and Painting of Concrete Piers with sixty (60) day completion time.
3. THE CONTRACT SUM: The Owner shall pay the Contractor for the performance of the Work as
follows:
Item 1
Base Bid Option A
$ 38,360.00
Item 2
Alternate Bid 1
$ 11,200.00
Total Bid Price Items 1 and 2
$ 49,560.00
4. NOTICES: All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
FA Remodeling and Repairs, Inc.
8244 Key Royal Circle, #636
Naples, Florida 34119
Attention: Carla Alvear, Vice President
Phone: 239 - 601 -0122
Fax: 239 -354 -8089
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page -1-
Packet Page -892-
6/25/2013 16.D.7.
Collier County Government Complex
Purchasing Department
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Joanne Markiewicz
Interim Purchasing /General Services Director
Phone: 239 -252 -8371
Fax: 239 - 252 -6584
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP: Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES: In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Contractor shall pay all sales,
consumer, use and other similar taxes associated with the Work or portions thereof, which are
applicable during the performance of the Work.
7. NO IMPROPER USE: The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Contract of the Contractor. Should the Contractor fail to correct any
such violation, conduct, or practice to the satisfaction of the County within twenty -four (24) hours
after receiving notice of such violation, conduct, or practice, such suspension to continue until the
violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION: Should the Contractor be found to have failed to perform his services in a
manner satisfactory to the County and requirements of this Agreement, the County may terminate
said Agreement for cause; further the County may terminate this Agreement for convenience with
a thirty (30) day written notice. The County shall be sole judge of non - performance.
9. NO DISCRIMINATION: The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
Page -2- c+9
Packet Page -893-
6/25/2013 16.D.7.
10. INSURANCE: The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per ,..�
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non -Owned Vehicles and Employee Non - Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of $500,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that he is required to meet. The same Contractor shall provide County with certificates of
insurance meeting the required insurance provisions.
11. INDEMNIFICATION: To the maximum extent permitted by Florida law, the
ContractorNendor /Consultant shall indemnify and hold harmless Collier County, its officers
and employees from any and all liabilities, damages, losses and costs, including, but not
limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the
negligence, recklessness, or intentionally wrongful conduct of the
ContractorNendor /Consultant or anyone employed or utilized by the
Contractor/Vendor/Consultant in the performance of this Agreement. This indemnification
obligation shall not be construed to negate, abridge or reduce any other rights or remedies
which otherwise may be available to an indemnified party or person described in this
paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of
a claim by any party and written notice of such claim being provided to Contractor.
Contractor's obligation to indemnify and defend under this Article 11 will survive the expiration
or earlier termination of this Agreement until it is determined by final judgment that an action
against the Owner or an indemnified party for the matter indemnified hereunder is fully and
finally barred by the applicable statute of limitations.
Page -3-
Packet Page -894-
6/25/2013 16.D.7.
11—N 12. PAYMENTS. The Contractor will be paid upon completion and acceptance of the Work by
Owner.
13. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work. The Owner may nullify the whole or
any part of any approval for payment previously issued and Owner may withhold any payments
otherwise due Contractor under this Agreement or any other agreement between Owner and
Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss
because of: (a) defective Work not remedied; (b) reasonable doubt that the Work can be
completed for the unpaid balance of the Contract Amount; (c) reasonable indication that the
Work will not be completed within the Contract Time; (d) unsatisfactory prosecution of the Work
by the Contractor; or (e) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other agreement between
Contractor and Owner.
14. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products /materials from
specifications shall be approved in writing by Owner in advance.
15. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
Page -4- �9
Packet Page -895-
6/25/2013 16.D.7.
16. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit an itemized estimate of any cost or time increases or savings it foresees as a result
of the change. Except in an emergency endangering life or property, or as expressly set forth
herein, no addition or changes to the Work shall be made except upon written order of Owner,
and Owner shall not be liable to the Contractor for any increased compensation without such
written order. No officer, employee or agent of Owner is authorized to direct any extra or
changed work orally. Any modifications to this Contract shall be in compliance with the County
Purchasing Policy and Administrative Procedures in effect at the time such modifications are
authorized.
A Change Order shall be issued and executed promptly after an agreement is reached between
Contractor and Owner concerning the requested changes. Contractor shall promptly perform
changes authorized by duly executed Change Orders. The Contract Amount and Contract Time
shall be adjusted in the Change order in the manner as Owner and Contractor shall mutually
agree.
17. COMPLIANCE WITH LAWS. Contractor agrees to comply, at its own expense, with all federal,
state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable
to the Project, including but not limited to those dealing with taxation, workers' compensation,
equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553,
Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith,
it shall promptly notify Owner in writing.
18. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and
waste materials arising out of the Work. At the completion of the Work, Contractor shall remove
all debris, rubbish and waste materials from and about the Project site, as well as all tools,
appliances, construction equipment and machinery and surplus materials, and shall leave the
Project site clean and ready for occupancy by Owner.
19. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior
consent in writing of Owner. If Contractor does, with approval, assign this Agreement or any
part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all
of the obligations and responsibilities that Contractor has assumed toward Owner.
20. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or fixtures
to be incorporated into the Project. Contractor warrants to Owner that any materials and
equipment furnished under the Contract Documents shall be new unless otherwise specified,
and that all Work shall be of good quality, free from all defects and in conformance with the
Contract Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement or 110 �
Page -5- (9
Packet Page -896-
6/25/2013 16.D.7.
repair. These warranties are in addition to those implied warranties to which Owner is entitled
as a matter of law.
21. STANDARDS OF CONDUCT: PROJECT MANAGER SUPERVISOR EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well- groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent
employees who are physically capable of performing their employment duties. The County may
require the Contractor to remove an employee it deems careless, incompetent, insubordinate or
otherwise objectionable and whose continued employment on Collier County projects is not in
the best interest of the County.
22. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
23. PROTECTION OF WORK
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re- establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
24. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or
the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice within forty -eight (48) hours after the
occurrence of the emergency, if Contractor believes that any significant changes in the Work or
variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations.
If Contractor fails to provide the forty -eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
Page -6-
A
Packet Page -897-
6/25/2013 16.D.7.
25. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner) is
ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or such
designated portion) is complete. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work to determine the status of completion. If Owner does not
consider the Work (or designated portion) complete, the Owner shall notify Contractor in writing
giving the reasons therefor.
Owner reserves the right to inspect the Work and make an independent determination as to the
acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment
shall not become due and payable.
26. CONTRACT ADMINISTRATION. This Agreement shall be administered on behalf of the County
by the Facilities Management Department.
27. COMPONENT PARTS OF THIS CONTRACT. This Contract consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set out
verbatim, including: Contractor's Proposal, Insurance Certificate, ITB No. 13 -6032, any addenda,
any Purchase Order made or issued pursuant to this Agreement, and any related plans or
specifications.
28. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer
or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any
County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics
Ordinance No. 2004 -05, and County Administrative Procedure 5311. Violation of this provision
may result in one or more of the following consequences: a. Prohibition by the individual, firm,
and /or any employee of the firm from contact with County staff for a specified period of time; b.
Prohibition by the individual and /or firm from doing business with the County for a specified
period of time, including but not limited to: submitting bids, RFP, and /or quotes; and, c.
immediate termination of any contract held by the individual and /or firm for cause.
29. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
30. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. No
markup shall be applied to sales tax.
31. IMMIGRATION LAW COMPLIANCE: By executing and entering into this agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by
the Contractor to comply with the laws referenced herein shall constitute a breach of this
agreement and the County shall have the discretion to unilaterally terminate this agreement
immediately.
32. VENUE: Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
Page -7- E)
A
Packet Page -898-
6/25/2013 16.D.7.
33. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES: Collier County encourages and
agrees to the successful proposer extending the pricing, terms and conditions of this solicitation
or resultant contract to other governmental entities at the discretion of the successful proposer.
34. AGREEMENT TERMS: If any portion of this Agreement is held to be void, invalid, or otherwise
unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect.
35. SECURITY. If required, Contractor shall be responsible for the costs of providing background
checks by the Collier County Facilities Management Department for all employees that shall
provide services to the County under this Agreement. This may include, but not be limited to,
checking federal, state and local law enforcement records, including a state and FBI fingerprint
check, credit reports, education, residence and employment verifications and other related
records. Contractor shall be required to maintain records on each employee and make them
available to the County for at least four (4) years
36. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by representatives
of Contractor with full decision - making authority and by County's staff person who would make
the presentation of any settlement reached during negotiations to County for approval. Failing
resolution, and prior to the commencement of depositions in any litigation between the parties
arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation
before an agreed -upon Circuit Court Mediator certified by the State of Florida. The mediation
shall be attended by representatives of Contractor with full decision - making authority and by
County's staff person who would make the presentation of any settlement reached at mediation
to County's board for approval. Should either party fail to submit to mediation as required
hereunder, the other party may obtain a court order requiring mediation under section 44.102,
Fla. Stat.
* * * * * * * * * * * * * * * * * * * * * * * * * * * * * * ** *Remainder of page intentionally left blank**** * * * * * * * * * * * * * * * * * * * * * * * * * * * * * **
Page -8- eA
Packet Page -899-
6/25/2013 16.D.7.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an authorized
person or agent, hereunder set their hands and seals on the date and year first above written.
ATTEST:
Dwight E. Brock, Clerk of Courts
By:
Dated:
(Seal)
Approved as to form and
legality:
Assistant County Attorney
First Witness
Type /Print Witness Name
Second Witness
Type /Print Witness Name
Owner:
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
By:
Georgia A. Hiller Esq., Chairwoman
Contractor:
FA REMODELING AND REPAIRS, INC.
By:
Signature
Typed Signature
Title
Page -9-
CA
Packet Page -900-