The URL can be used to link to this page

Agenda 02/12/2013 Item #11D 2/12/2013 11 .D. EXECUTIVE SUMMARY Recommendation to award a construction contract to Community Asphalt for Bid No. 12- 5948R — Immokalee Road Safety Improvements Project No. 60016.4, in the amount of $1,904,344. OBJECTIVE: To award a construction contract for Immokalee Road Safety Improvements to Community Asphalt Corporation in accordance with Bid No. 12-5948R. The purpose of the project is to construct paved shoulders and other work to improve the operation and safety of the road. CONSIDERATIONS: Immokalee Road is a two lane roadway with 12-foot lanes, without paved shoulders. Several crashes, including fatalities, occurred within this segment during the past few years. Crash records between January, 2005 and May, 2012 indicate a total of 199 crashes in this section of Immokalee Road, 5 fatalities, 29 injuries & 165 incidents of property damage only. The project consists of constructing safety improvements on Immokalee Road, from Shady Hollow Boulevard to a point 2.6 miles east of Oil Well Grade Road for a total distance of approximately 9.7 miles. It includes the construction of paved shoulders (five feet on both sides of the road), guardrail installation at an existing box culvert near the southern end of the project and at an existing cross culvert near the middle of the project, installation of a section of centerline audible-vibratory markings and pavement markings to enhance safety throughout the length of the project. This solicitation was originally posted on July 23, 2012, and five bids were received on September 6, 2012. After review, staff recommended rejection of that bid because the lowest responsive bid was approximately 30% higher than the engineer's estimate. The Board of Commissioners (Board) approved the rejection on November 13, 2012 (Item 16.A.27) and the bid was reformatted to allow for lower cost alternatives. Staff advertised the bid for the project in the Naples Daily News on November 16, 2012. Over 1,713 notices were sent out and 58 bid packages were downloaded. The following four bids were received on December 18, 2012: Community Asphalt $1,904,344.00 Old Castle (APAC Southeast) $2,039,569.79 Ajax Paving $2,217,757.40 Wright Construction $2,495,539.38 The bids were reviewed by Purchasing staff and the Transportation Engineering Department. The lowest responsive bid as submitted was approximately 5% higher than the Engineer's Cost Estimate of$1,813,582.00. Staff is recommending award of Bid No. 12-5948R for Immokalee Road Safety Improvements, Project No. 60016.4, to Community Asphalt Corp. FISCAL IMPACT: Funds in the amount of$1,904,344.00 are available in Gas Tax. The paved shoulders have a life cycle of approximately 30 years with annual maintenance and operating costs of$12,000 per year. Packet Page-786- 2/12/2013 11.D. LEGAL CONSIDERATIONS: This item has been reviewed and approved by the County Attorney's Office, is legally sufficient for Board action and requires a majority vote for approval. -ERP GROWTH MANAGEMENT IMPACT: The Immokalee Road Safety Improvements project has no impact on the Growth Management Plan. RECOMMENDATION: That the Board approve the contract with Community Asphalt Corp. for Bid No. 12-5948R — Immokalee Road Safety Improvements, Project No. 60016.4 in the negotiated amount of $1,904,344.00 and authorize the Chairwoman to execute the attached contract after final review and approval by the County Attorney's Office. Prepared By: Julio F. Ordofiez,Principal Project Manager, TED Attachments: Bid Tabulation, Construction Contract, Bid Analysis Packet Page-787- 2/12/2013 11 .D. COLLIER COUNTY Board of County Commissioners Item Number: 11.11.D. Item Summary: Recommendation to award a construction contract to Community Asphalt for Bid No. 12-5948R- Immokalee Road Safety Improvements Project No. 60016.4, in the amount of$1,904,344. Meeting Date: 2/12/2013 Prepared By Name: OrdonezJulio Title: Project Manager, Principal,Transportation Engineer 11/8/2012 3:54:37 PM Approved By Name:NauthRookmin Title: Management/Budget Analyst,Transportation Administr Date: 1/10/2013 11:42:05 AM Name: BrilhartBrenda Title: Purchasing Agent,Purchasing&General Services Date: 1/10/2013 1:06:46 PM Name: CalvertEugene Title: Project Manager, Principal,Transportation Engineering& Construction Management Date: 1/10/2013 2:20:56 PM Name: MarkiewiczJoanne Title: Manager-Purchasing Acquisition,Purchasing&Gene Date: 1/10/2013 7:21:50 PM Name: WardKelsey Title: Manager-Contracts Administration,Purchasing&Ge Date: 1/15/2013 9:43:32 AM Name: ShueGene Date: 1/16/2013 3:59:01 PM Packet Page-788- 2/12/2013 11.D. Name: AhmadJay Title: Director-Transportation Engineering,Transportation Engineering&Construction Management Date: 1/17/2013 1:50:58 PM Name: KhawajaAnthony Title: Engineer-Traffic Operations,Transportation Engineering&Construction Management Date: 1/22/2013 1:55:39 PM Name: LynchDiane Title: Administrative Assistant Date: 1/24/2013 10:08:21 AM Name: TeachScott Title: Deputy County Attorney,County Attorney Date: 1/25/2013 12:13:47 PM Name: MarcellaJeanne Title: Executive Secretary,Transportation Planning Date: 1/28/2013 3:50:17 PM Name: KlatzkowJeff Title: County Attorney Date: 1/30/2013 9:21:13 AM Name: UsherSusan Title: Management/Budget Analyst, Senior,Office of Manage Date: 1/30/2013 5:38:49 PM Name: OchsLeo Title: County Manager Date: 1/31/2013 2:37:28 PM Packet Page-789- -06L-aSed Ja)IDed N �— f` .. N m _ -° 8 8 8 8 8 8 8 ,9 8 8 8 8 m N 8 8 8 8 ° 8 8 8 8 8 ° S 8 N 8 ,-8 '� O-6-.{(') O d d (7 6 N O a) 6 O ni 1� O C Cl (6 0 2 6 t] O ai N r: N a Ci-"dam O > F N'--°. O O N O) m N 0)pp N N O O 't a) m p O O N 8 o) 4�'"'.' (0 O 8 8 N N'-fl,,,M u) a) u) O a0 S a) a m N O N V O N N S a ' .. N m 0 .. N ' w g-to. O ) O co w(p c a o C ai N- N N CI..m4".- N- 2 m .- c Y Y Z>->->-Y Y C O O O N N CO co'tA-..SA. '_) V N u) .- N Oa Z N `� J'` s( Q J/" CO 69 to to 1A A Vi 69 /A 43 69 IA M fA fA 19 NM 19 fA to 499 N M Vi to 69 lA A to fA 69 69 H 9 W 8 S N V N S M S V O T''0�.0 N O S .°- N (�O V`S. M S 8 S N C°O S T a°D S CO U Q pi; (p C O) ni n:_-.� 6 N N N C g m el 0 O .,,(0 g N r0 a O 49 as Q • a ° 8 «, (N ..- A4 N ' a) ° C) a S a a) � X 49 0 Na (D 5 N H N CO i A f9 W `�,�tA, `° 8 8 8 A m S ° A 2 S N a 2 2 8 8 2 m m 8 g a q 2 f2 8 8 8 N Z ^ 8 O S O C O N N S ° N A O ( N S ci� 0 t of N O O - a) M O 0 8 pp N - N 0 OmO o W uaO (V N N N 1.9 CO Mt O 0) co- N N co' O ($ co- N N co- N d v 0> 0 m m N N of co- m m o *• fA O O N N 4 N CO 0( Y Y Y Y Y Y Y Y 2 N t0 CO 40 a I- = N of to 6 to 6 6 6 H 6 ui M 49 fA to M 1A 69 49 to fA W ui f9 A to A fA 69 ui fA 69 u9 N to K a (p �p a� pp Iv- 0 - 0 W < 4 ON- a) r g (NO N S M N 4 N N m IA M r V m ui °a) N (o0 N O 8 U Oi .- a) 6 O 7 ai h N ai O N r: N ni N N of n: V' N r. C) () Ci C' g C (0 E N 0 CO 69 69 co 69 fA 69 a s M 2 a ° ^ CO NM 0 a N 0 i9 C 07 Na) a) f9 `-' m a) O !A M Q to tla N to di �pp !9 CO' fA fA f9 fA Z a) 13 Hi z A 0 0 0 0 0 0 uvO O u0 0 0 0 0 0 0O O O O O O O O O O a0 uO a) 0 O 80000 0 0 °O.yf O N- O O (a 00 0 (.(pp- INp�, S0 (0 0 0 0 (0(p 0 o 0o O 0 8 0 0 0 N- 0 1- 0 z• 8 S L to (m0 CO CO 8 CO a) (°0 0 M N 0 0 N 0 N 0 N S N 8 0 S N S S ^ m N Z N O O u) fV u) N a7 O N co- 0) u) 0) (V O IA a) ai C Oi C N C) h CO- r C Cl) E c v CO (a CO co o « ul CO N CO o Y Y Y Y Y Y Y Y ul a 2 < M I- N 0 641 iA to 69 49 ' 69 U) 69 IA A 69 o 69 69 " A H t9 69 9 A 69 69 A to M 69 69 69 A A N 69 O O 0 0 C O N u) 0 0 u) O N u) 0 0 CO N- 0 0 0 0 0 0 0 0 CO 0 R 0 N O 0 W Oo 50 O Lc') V o m C N O N- (a) r� N- O o O O (O O (O 0 0 0 0 0 0 ' O 4- O n 0 pO E Q d N 0 tlf °tA p0p NK iA N�, `� NA 1 ri N 0 g 0 :A 0 a) (D u4�, w w c0 O F N a 8 ap iA CA. A f9 G Z H 4 to E N d 0 0 0 0 0 0 u) v) O O O O O O O O O O 0 0 0 0 0 0 0 0 0 0 0 0 0 O 0 0 0 r e 1 3 (N O O N O O In 0 0 0 0 (O 0 0 0 O 0 t0 0 O ,- O C 0 0 0 V u) N- N- 0 0 0 0 • CO S 0 u) 0 0 0 V) N N N O 0 N N O) a) O ($ O V7 O 0 N (0 C) N O N Si♦- S (D O 'C u) O N • CO n a) N N r N C N u) N N N m 0 .- m N r O J Z N V (O O O 4 W to N ) N n N V co O (a ' O N- .- N O (0 V (O CO .- O M v- CO C 4 N CO- OS N. CO- CO- .. N CO' C) N C. N. C o V n - N N co' W aJ n O . 0) V' N- a) v v O C) N N- N CN ro N (S N o m °m Y Y Y Y Y Y Y 2 sr a f cr N ¢ M I- d a } 9 F- fA V) to fA t9 E9 fA t9 to 19 fA fA fA t9 fA to to to to (A 69 69 fA fA to fA 49 fA to fA M A M to CO ° re = ° ° ro a Na) N ° o c S ° a ° m 8 m o o N m • v o uu 0 0u0 o o o o co 2 U ( u O c o u) C u) Ci 6 6 ri 0 0 u) n N- N o ui N .- o A r) u) v CC) o mo d v 69 e9 eA (n iA «s 69 A «f a) 69 � «A N N � 0 iA CO ((a°_ 69 N 'A 69 N 4- to N 69 eA CO 44- E m E pp (pp (pp Q,Q Q •- •- 8 0 o 8 m V (NV N O S m N N N ` N S (0 CO N co co N m N (V a) a E ~ J N }U J J y }U } y to O to to } t Z ¢ to U LL W Q ¢ n} !¢ a¢ N¢ Q W LL LL = .o N F. C U 'a W O 0 U O 0 0 U m LL U a LL 2 Q LL in i0 m N E m K o .,.[LL 8 - tw- W Y t- 0 F- H I- v o ? U. U Y ¢ 2 2 2 N q ¢ Z 2 U 0 CO W �'a >- K F = N W W To" re U Z U U U 0• 3 F- - iV z z g w W co a~) y w .o w p ? z zcic_Y) = vaua � g QZy W a55 LL L , co U O m 0 1- IS- tp }w Li,a a to o U to o Z cC cc o # 0 N 0 W• U O = K J 4. Z F- f- la- o t- J to O W , 2 2 2 W w U O LL J a p g (P p U U Q M., (0 U W O W Q N f- f- H W J aa))LL, ce Z 0p W =O =O � 6 0 co p j z 3 1.- C) 02 °- u o 0 0 0 0 c H > j m LLO a co Z rr Q C7 (� H 2 2 ¢ p W 0 F CO x H O w w ¢ c Y 0 0 0 0 C C j y 12 o cc , J W W r.-1 3 w twn z tan tan vwi t'f) O p Z W w Z Z Y ¢ d a a w m t j E , x- Q'NO a�i Lu Z U ') O] t- O Z Z m Z ¢ ¢ O ¢ ¢ W O to Z a ¢ Z J C7 p Z 2 tr K K 3 W v P w w ,y d EN L O Q U U 7, O O 2 Y m m i_ > > Z w t¢n" Q g Q § Z to to 2 � Z r~n m co"-) a 5 Q °0, m 9 o ' c 4 L w ,` Q Z oC H K r Y m U ¢ ¢ O a a o w a a CD 0 W W U U U I- a7 m a c g m '�.... m m • w W W O ¢ ¢ Z m p Z Z J W (C a 0 O D m ? 2 Z Q 6 6 m d W re O O rt d a U W Z K 0 0 0 C4 Z O t_~n a > > ¢ LL ¢ m Fa- u x '2 m n 0 E m E- a''o2 O ¢ o } H t- x 2 a a > > m , F- O a o N N w c? x x m ¢ ( ie U N a O m 0 a , 9 a a) g m 2 2 0 to to to w w I- J O O t- w to 2 2 U Z C7 C7 O a to w w a • O a H H t- to (n t- 0 ¢ m 2 co in)i J 5 m m 2-cii as .a. u_ c L_oziz 1-iz 2/12/2013 11.D. Ad 'ronisirative SenticesDivision Purchasing Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge#030160) COLLIER COUNTY BID NO. 12-5948R Project# 60016.4 COLLIER COUNTY, FLORIDA Brenda Brilhart, Procurement Strategist Email: BrendaBrilhart@colliergov.net Telephone: (239) 252 - 8446 FAX: (239) 252 -6697 Design Professional: Growth Management Division Transportation Engineering Department `11.1 JF.r Purchasng Depar'ar ent•3327 Tamiami Trail East•Naples,Florida 34112-4901•www.calliiergov.net,purchasing 1 12-5948R Immokalee Rd Paved Shoulders Packet Page-791- 2/12/2013 11 .D. CO T C 7 rL Email: BrendaBrilhart@colliergov.net Telephone: (239) 252-8446 Aiswe Spices Division FAX: (239) 252-6697 Purchasing ADDENDUM #1 Memorandum Date: December 11, 2012 From: Brenda Brilhart, Procurement Strategist To: Interested Bidders Subject: Addendum # 1 —ITB 12-5948R- Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge#030160) The following clarifications are issued as an addendum identifying the following changes for the referenced solicitation: ADD: • Revised Bid Schedule and Plan Set • Revised plan sheets showing the Audible &Vibratory Pavement Marking. QUESTIONS/ANSWERS: • Q: White Markings -A:. Audible &Vibratory Pavement Markings (Bid Item) is being increased to include the edge lines for curves 2 and 3. The original bid had the double yellow replacement with AN striping only. The quantity was double and the bid item changed from 7-1-11-211 to 701-1). • Q: Guardrail -A: The guardrail installation at the existing 30" RCP will not be installed during construction, the construction of the mitered end sections will be done instead. This change will be reflected in the SFWMD permit certification at the end of the project. • Q: Pay item Optional Base 1 — is this FDOT spec? A: Yes • Q: Any night or weekend work? A: No, and lane closures will be restricted during project. • Q: Will the road be staked with Station Boards? A: No, measure in field. If you require additional information please post a question on the Online Bidding site or contact me using the above contact information. c: Julio Ordonez, Project Manager Enc: Revised Bid Schedule. Plan Set 1 Packet Page -792- 2/12/2013 11.D. T 2 0 z w a 0 Q i. p O z o` 69 6, 64 69 664 69 6, «4 «969 69 69 CA 646944E, 69 Eft69 44 fa 6, Ea 4A 64 964 69 , *. J 0 °J I- o F, (J1. �; .�,.: 2i', D r r O pr cocoa) N N 1- co N N CO N.," N 00 0 a0 O O N O m N N C0 T o OD V N N O � ) C F a) a) >- LC- LL a) Y. >- } } } } Z Z Z ... } CL a a } a) an a) a 4a < 2 LL LL I Z J J U J J J U 0 a) 0 co a) a) F- I- F- w co U J W W CO < < < Z W w Z J J • m 6 < o w U cn • :,. N N m L U 0V > Ql c4 i Q F- § LL - N LL z > co w w H W Y I- re Q Z 2 U ~ 0 m w m Y 1.- S W , m >- .n O r F I F- = z ¢ O v z Z w U g S g w O 0 W V) LL lL :.R.-: > U U ,.-I Cr)a can 2 _ j w a a a U CO O Q U U cn �- y R LL V ip Q F F}- a -- 2 >- ~ cc W W W - Z �; OLL W 0 ¢ r a) O D U -1 °v� ' Q w O w F w H H LL Q a xt E a a - z z i g y, 2/12/2013 11 .D. W aOcinrn TVAWD 2IOiVO JO isva d'IINI 1 Os 'cA'IH 11OTIOH AQYHS woad saxamaAO21dPU ii ?Iaa'InOHS aaAvd (9t8 .To) avo2I da'IV3IOAIIITI ITOZ/ 2/90 - SNVId °COOT 1p fr E g O eN Agm gc_ r hN<m a� 0 „,..400Fradoile.- i s3,901 4 :�, � W H°e C5!,13 b7°¢; �Ioe. �� Z GriC° r Nyaj p�p,�OUZI22 aW pry= ]]� V pN�rt l am z63F gg p C yFa�U OOa• p rik — _: 6 O d� tit.:f 1 o ~ < z < < .J V C CD ~ J 0 E Z H ° o U U] a E-" ccc~.>°q° owe w� 6 =i W zoN QWt+O �WO 3 °t �' W O o Owv0i <wuI-� Ua z 0 c'o Wy > O O Q 3° Z 0 a H O WZQ mono wmUl o a . C/D 1\ippo. p- ° . ~Ao ®® yi Li W C0 a �M�� 111111 n F O • �Gn x�i�� gL��! r,:11 du i gB Of A -.7F H — ,■ #.yy . U $ .a d"y 06 G yia6 Bg S Q W Z az ° z�e $ O . ■ 26: ■wad2 u" ■a ■ nq 0.4`" ? F ■ 'i fi -J �. q I 6 grt B 9= 1-4 O z x r.,-, OU WA' 6 G F-- • c #"ZOO?S e 3 9 i : " - Z J Q k ~, m x�A �W ° i \ r gl; @ R r _ a+3q a u— SI1.1Fil e.aF- 2 w o < ii_ -'\ 74ST?B:iFC6 £■9i3 9@:!. D,�,,•vx g O m al z, 49 41 41 41 = �" U � �r4 W 0Z O '¢ a ' O z<E + o F QUO O wfr< • F-- i c p Z to No 0_O >z o Z r--� a,x a w o .c 0 Napm m -E $ 3 B 3rr<z R._+ <ccg r ry � q <E<z zpp <'tl Z2 -'' ,l r 1a1� rEpOO,� Z9iFgrp < < Yl R° �� ONUWC Ce<Gmfoo ill al bL 8 >-„22W (p�{l�r r2'w�Y Wm�J« 1 N<W 6 NAi E oar Ed°e a ;la CO N p<< ; P5 grcO ¢S B '3 S ce �. 0 � <K�WW� <W O ;��O C �� 7p cqj W p 9 s ; : 0 «a ZW nr<N 5 O r zgtiz Wz ¢z ‹,4 . Vile UU 0 4,n r: 2 w Z Z ry j = OV �z OiS O W m s LL dLLLL d d -i '2; '="1 al a n Z rN aiawF wz .. m* �wNme- W KC<c, lo 7� c N.3i-a..i::J'..'0...1 s..D .L+ •...... ,4. . + D.J.. , r__. Y,rv.. ,. e , -YAlYQk\Y:ail 66u46..A ...vE ns.,JOOAY..•. .. Packet Page-794- 2/12/2013 11 .D. 3 _�8a �_4gP 'N�Soml��l� 88 b aG m ��py o m {<� F. rp O ° ° z a E" ~ 6i ° DI J�> II.N>� >)-»'S, z<l:> ,..d<>mNN «< W.2' 0 o 12 2 V O° g!'3R1 1 m61 U O U .W-.0 NUN NN1+1�1-W N(7WWNdd<2'W 'tL -�?e ° _ < i �Cc$ N � 00 1a m 'm. F5c ;E':-_7 Q m 90 DF�c s� m� �o a ii?. 52 m 3� -amDg m�° m oc��g m o w b hg ° w= Q ta�� 3k ° I _ S O tn, = ,g 2 W kr,,Fig E E tr t. -FEE SMR°o°d @ Ooo Upx 0 F a (m °%y Nl�.d N w<Q¢2 8 Q �O+ 0° it [ -0° °O g F 111 =o_ • 0. W 7i S�UJ-W w>>,KIW>��u(ya�.1 Se 7 W 66 CNi °F 4 rL G� ° �j 0...O�GyW�CO'CO y ■ • 0 2 - t9Eg1.0.TF'�G 1C . 7 pSI$s-jO ZOm 00g O Fn� more-mi'a'° 0 01i �� v LLsc w g�wi'2Z'zkF 4WO W',�P+E-ss /1i EEsi m Ao T.m81,92gh- a W ¢-" � °E °�z x o o !!e z &��°o .zyZaw L° o��"I z z Dzm� °�� °�8�8Dwmsm i ... o oUU Qa Ya m�CG 1L a <¢ x <wiNxs'" o rc��w �o Q D w�-3 mz m eee I-Nzp xxau �❑ °2N,�,w�dW000W o� 8 '� °� ° °ADZ ° o �� a3W v�imyaY��mG;i�< L�[uza� zwwu'7 Gn° vo�2 °o o° p�y, � zg,> °1° � fill ee py� k. .7 QW�4 . WNN2Q<O ❑°D�UW = ¢xQS.s� aF U ,2a®a® Y< Ll 66 U� lie Y� U�yCg�QYm V»"WWN Ir/¢id�D Ia��¢¢g 8� <�SOPfi � � m ��pQ °<< {GCS I�~ o a�5wW y�moizo�a�o� ❑O��N my �w�y�..e `°1/;;��G�a R"�8��@g m • �.�' 1-g a �a�l�y o �r Ell' W aa� < <aW4ga:aawz$gaaz�( a <zEa ° Yd° pb ° e�0.0.0.+++= g� ss�'cF`iwu F"�F pp>II�� >>T�a J Cp 3-.JxWW52 xpm E+ S''ziiii W JO El'aig C-U'mtl4 N W aO a-r N m�j a1 at a V�t°.1ppoep1 W C g .L B.Z$tttvtlpppQ 8 We.�"z as�D Na amp W �<�8.d °N ^4 Zp - T mplyN�Ri i D vo$ [� m8 fs7 � - rR °rS^ offi M � d �g ivi� i�i a in�C.l. I GW o.d�ao 'd� d d e0 P/eU wo I°° o$° © ° 0" ogb^$'° aNm� $n °n 5$� ^10.t ��aecoam cu So c� �dS �� • zc NI i o W z Z°...cn J m a W 88 ° WUh U " O Zi R < m°d �N xN < ° wi cob � m m VQU p ZW m z a9 4 p R'` p, <WiS - o Sj cWrT ! '.6 a°°-b v E im ICI. ;111!1:° C°8 ma ° Qa xJ 1 1 W'z_ R 4 a z= "2 3 i z orb =.s W vmJ o Nk0 }o� =:c @-° ®® oys P pzp m e 1E � O 3 T „ g:,.,-,9, f 1i.'{ a Ti E4"'4 '!"-‘ P li 7 w>z' 6ID iWO 7g a x W °hl f�UO� m a o8.. ��QSy3Jt F Qr N<UU g° m '4 FW S O gm x C .i� � m . m U O� < Z< 2 Z 0. F �U 1 � O °F °K S m jW vl Ud_ ��yw IpS�H m � ppi a "'om.�o�0-° F°• p e�°< -_,..� yyx�1p� ' 2w Jo .§4� m� yJ y.g V.a= . n j g tg IpPpiRito'p g t B I Fm °m 0 0q1'ki .'lig j41< 3 Z' ZU P. -F5 T i< y'.' '.7; pw 14N q °,11;'"$Q � ek'QFi 1' 1 o1 mow ZO zCCC5111 f/I Z �� y LU W �wm� �8� o o W� z i g�'�' � �� >�I- �'o'N i w� a $ s p°1°�Lyc+��m° �� [r p�i F 411<.SYr Rim g yyi§ y?�?W? s CC' yq Ti< pzp� yp< F0 rca "114 °hyy1m.." ®� < % O V Z pti 01 E 9 0 101 g0. = "1'g < Op� o~ D g <,�T;W3 =F VJ139 g.1 W v,< BEIGE<® �1 �p ppp111Eo "V 04 p3;:,:- ,O�,,,Pa C qr, I� Rimm O !e4 go K O <m<�y<] ~I/FOI/�1 R<0 D a ? 12 UCYfM ..' N. m yY DXp Of 0. 0. mpi rj►Ft59G1 gm2g g,V10 WSW j YjZ OD OJ < °NWI" yy °m1 Sy Oc"14 °wU O FFmU W 0 Z8 iC m,EF W°G F. {{�� yY� W f V�< 5� L< pF - :1,•' < 1°.,F�m F6 ° pp O Iym o pM O�ej v1 � t =� 0 p 3 ; €5 FZ W Id!! urn gZ KK j 1 < W2°U ° a�<i" § ' g-x"W � � FO< O R23 g � � NK 2 W Y 3 ig of p ff pW zpUF�° . < 2w=W`dJ' i ojz� W¢ pTq qT p pzp p p p�` p p of 2-- fU n mU ,:e Q{<F mOOZ c.D, N :: 8F2 ^. ''''OFV"m N6LiN7 W<G Of bO hC']m0 q © °ay o� z o< ¢ WtFw N g zo mggO o�Ea um F R "� < o� a mR og9 d Po o s.. U mm �? FWF -g: En Gg g <> R NV 000. �Om �r�oZ ya i 65„w4 m pig gZ� F 0.F O°O ;g _NZ 1-m~:°< <Wp B° �<3 z�6u K>K� i ° p0 U pJ WS O <<o mJ SF� UK<O a �J8 O OCJ r! ; az,F5 Z WN °Sgzv ¢m2 U OQ wry nn N tV ppi r2 �ZN8 ~ = yOy�FS� � Zn�pKjK1 VI0CiCEE f- U-�WO ZU m�V Frei 3< Ilj NN IUD I 7 O Is W�F m0 � hC w °O WF CLr7�4$ i m Up 1/1 <W « Writ< po I. NAp bg h10p N;74 :i., W rig< 4U O01 <ro mp00 W ZW� << ti� j�p. �F OF � r!� b0 A.f •f �m W° �Z 02� y�Z<°rm °�p WUC �� s 6,!5 ;w> 13 a W zwr`J' p ao 0o wpI o o w S� !:(1 '3'< dim E' ftE Fxm : -U .9 - O oK 3J 33 >�J.1 3]1 <VIp z0 pJp �� nn n�f n n m< !:(1 HT pmH ¢ 0. U F W ZWim > N3 OW gUW F~ NN NN N"1"4 N ' , ..,6 Um pm'�ZZ g� U W OF UI OrJ <,,rr�� Jy - y�W WW1- LL p«m < ° d ,,3i< °w <IZ.I m�171 � N i�'6 dmo rc�< zgE�nX <itTTff m xZ?=CTm �y<<1W y� yW � �p <y~ apq 00� =Is' m0W J1<UW�S �4.V OW3 E`itl ;,; (°j FOWRm Fm K� Ji I-W< Vx< U J Kg =m OW 03L2d W "fq5. T K3°m Ni; w�1N ae z<Z JOZO ZOr R.Ir U �L p ww y Z K !P ti K FZ D iii,-- WL .:K< • !1l!¢, pV si. imu ¢O¢ 00 <D=O hl 0 U 3N !Z0OO T mw - <� W O< F N d m <er qq U~ ;<W2�g xp 1!"j E'-2 O �F2 JOB U2 C j gr0 w? NV.W 0.�8 °O 060 �Ltl R pWA� DKN y� OZ .,ii � r]=pCp WO W<¢ O - JFyH OZW ?7�r '-,`,.1. 1,;, 10, i < vI g Z m IJKO uUl`U�F �� << �Zm WgF W� Na �JJ W W UU{{ N U Q D G< K �Jg ip F.F O N 02-K �p 3 ZOF- U Na K W <4.I =J�K CFT U�.----.'�. O `Z` Y2° p< > F-O �� Wvy�43 N� g O. F J I-3 K U>m, f ji O I dxUOWyI< O g� NOr_ yU �� X< <U SV W< Z C` <2 YWJJ°j 63-Q�52 =< k:�44TF TK�p � Xy�a ��2 j�j �o <2 �32m =0 QT�¢¢� E m?�UOC N1=J WSQ ��r�k•��n O<g U m FUU mLL U6= 0wf -� WWOU VZ° 0 <g �° .y F.Og �; z `.L O a <O 00.R��m OW Od My.sa �� o a < K< < F<�z � .3 <3v i 1`w >>< 6.% <° NWT U •z£o_,g< tKz �,. Y0A F WZ F 0 TE° O KZg < r o <F3FZSF 5h iz m < iZ<ZU =� k $$Z z- g zz < zZ INyE t °F awVw�.°1.11TUi 4 VD JZn 4,pu u6 .? § 1 iw <� ZZ NI !Eigg; 2g:qn Qi her 2 y y yFT VU WO2 ww CU : pOKW< 20 U O U > N� 7 0.g° gZ Nor UZ 0.0yvy�1ZOZyZ S`�Obf'o�Jd $�A GT6 xt 1-1 K°<'R W U✓ 2OO F xZff yg 1ri IC X W L2 W z OSg W NW <0.�Wg1 < F<U �US� Z9 WJ� F2F � V trW � WW wwW. �<GV WUl W �U piW �~Sp-S kGCC CC .�1..�� r-.IJ30< O�Op IN W FW. WF < F F .� < K :U W�WO NU °_w a_�_�C �O NF nmO.U3 aW In ZF 7. , 7i-i J0.' Nm0 U g Jam.n0 ' -:-'2%:',: .'''!„:".!,,,.m <Ow C. Z.-� ! i� .._ . . -5.. ._ ...�.o a. uo . .. •.� ... cool U• . Waa.6uu••u fl w�o me.wli Packet Page -795- 2/12/2013 11 .D. •a `n6 " 1 d0O en N amoo Ey i< N J Y j • Z N m U W W r •� Wd°°N < �W WJZQQ C m WWZ fin+ as C7 ! HhI m FOm W 0 O° �� y WgEy z - o z Y 64 ,NO V'II WGa OM °a 11 V� c�5 T s N W U N J O d 11 1 W pp W W . ZZ yW pN Oy .� <J<N ! hiI U N I < W 3W ^ ..,^.tic\ OWo 1II,� i w<a= fn aw`O1m a :pp'o p'Q a N ?< m W 7 m C1 d III gN {iU N 1,i , ° . •r, ��I g N m 0 -y z O ° w son E-, J \ O �T� aN W R§ /N W a. W U W O x d w al Q Ui 17-2 �NW Uz °01w 0 ...4 sor WCT�z NQ ZWVW jav $- Iy f Q W° O m m N w U z J= y N flp' , a Pvz KW ono mO. uw.= 4 W C 0 W r W Z ~Z W N w• 02 y �U W� O8 ~ Z VO N N Z W° Q N W O W NO 7 9-o W wO al W zOz N� b- 0\ ` v < � W 1- k° N Qv ] W� xa o°r N�* N ' J w F 0° lj pvU O gy N > I • .E z N W Z W 4 K B C CO o • <z o= • az°z ZW <EL, a°,A k c-5 g0 .3 a3hVd �IJ WNow ox Uxo CAN co w Z Z = ? • G y�•Q '_ / Z<< X?O X?W XN W XX W d.' © Cv:�o>>�U K W i I DUHN Wm< WKy WW W Wt f~/1 S w a�4e R7••N< li:, J O� rJdU •,71? �fHN hZ 2 N 6 g WJ p� �n > rT m W «>'I\ V Q l„ NNF Q° Y o o N F 0 z i�t O i Q. a rr °a. W �I 4 f+. d ��f 0 _ . f1t N2. W € IA W t5 Z WI- ® l Q ,` O a o `'''X 6 o p''z Z w 2I w N:...z 4 Iz �1.____1,10-1HS a3nva '� x r:.. . >. �� a' ey N - W ��'° v �, Oii , W O O�Q- 1'''. w_, ° O � T .--(1-; . oU� "' i, N� d N..W E1 N Z N H i x-O <p v Gg1 1 K. \� < a.J Z 3 N z NN =C6 2Q 5 �O 3 N Rl �^ I , C.) I-. In En- N O y m V■ N� i xa ra o8 l� + a I <W 2<4 '4 ; z �� QI N2 . , ! - ro o n• p z A N V1 L3 d c°.>a w+mil /p� • W • :.: l v� N Q W {aJ•2 ® Zyxj 0 aQ � � J k N I N 1.- 00 4 ,i,0_li W tn Cn \t I aQ' W N �' < Q U I�, 1S3 NV 10:£Z:ll ZIOZ/£l/ll-6x,v'£S1 NOHSNONN)\slul3C 8 uold\l A, -__of\S103POldd AtlMOtlOd\0Wt ufilsay\6u1J••u!6u3 uogo}uedsuoJi\:O 4*®kl1 Packet Page-796- 2/12/2013 11 .D. co cc z w •",s-� � � •a N O z o 0` o°.'4� J Z w< U d O o `•21Q1HS ' 7 7o o . G ' 03A-V d ._ oy,c0 I Q te 4 g° - ' .0 t, ' w ^ ' I OSIW I 1WAd n- 7" t � OSIW o ° x � r" I W R: iiae1-71,1�On <u ^ � a� �z to mist < o i t $d as a N/O.a a 1 _ a I u,a 1w> :.in�.,Tn Y i r x" , O ' o9 F. I L.-,,,z C E{ p; 2''' §- :411(: W 3 ;uh Y <l _. _ O'z I s r I • E. ,., az.)..,i ,..,..,..,,,,.i,......„..„., .,, ,,, t\I W" W r4� N a I f�l Z :....=,W 1,7%,,, , z N 't V 1, w L "te�' .4,1, i zxc.s ` i' C7 w E-,y t- . ' �I .. _ n wo 2¢..v ,'wf w x z at J t• QQ.~p�f, ,'l v yp m x k' # K I I I d w� ' rc X =a c)i d �s �Z c.I m o „ x 1 IZ p, a i CK ce c , • ra ff B w � Y jam � A o ils m III _� °. Vf r f t _ i F' 5 !, o EL! Uj o { m Q j I tLI - y a' w n z' W v c °t- m O O Z ,T,8 ~O a�x g 2 t (II xo �z �= w w �z s w r !Ill r z z r wx, > Q ; �a1 ' : lk 114 i o 1 , H s 1 o Z �k - ,1,0 w O W ! z L� Z i i +` z{ w j r, ;s p , 181!.1,i O � 0m Y �LI '�F a`�` � „ iii n■w= .4 I oU s 5 �,. O it I.: o d i1 4— I V O p r i 7i: ,.a 4 p as ' OlH5 I c4 . 1 m, 03AVd _Iw e �+a — 4 c u > U --� �-- �0 . i1 n �t d°�on1 -+14 o,T> o < 0-03a: , n 1 aI Irv- izmw< 0 11144, *. n ovNv� I ui x r a 5 Packet Page -797- 2/12/2013 11 .D. 1 6o s r ec' < I r IA 2 N zl •NN 2 L,,^1..On 1 I g y– — I ° 8 g2 , I ° O m IA C51AVd g WWy CC 0 - W ='d I Emc o W U N = pp NZ < � n I & ' *-0 TOJo W� IN p 452 t .* av ° N 'J` z 2 as 81Xo iii VS r ! n U *. a u'5 <*�� i 9 to WWa ic 1.1 = 604.N° y .4 2 ? N Z O -'5a6 64 ¢ r�o i; j W o w w o w �° I z I b '' 0 I I � an ■ a z J N9 ' re x g W _r°s a I z �O 4 % (g rr C7 E'w' w z. E. I ba F A L-,-N 2 773 I J 'O h K D ' U /�p-( W o OUaz.C C y � r g g..= l L. O 1 m A 0 I- , z o p cs,Zd' Aa aN r Os n O a r I wt-<5 n _ J W Q, Q o �N� I °665 r _, - i„,-.7 / XX o XS -0 .....LL °i WI6. rO <a. y W I �� O — J ;.13 ..1 e I fy--- IAN I C4 W rW o N� III o 16211 �; OI oF��WU wF OU g W U � O< a yy a. r SrF j $ °W Ina.axe .. <a 5 Ina. a 'nv=) °n r I e° e c) S ore J <9 N d 3 ao O U inN ,,,a1 pp `c-''-,W d >2 a&� 4 <N In 0 ,`2.-9E ,k C ir4 aF e !V/S lL 7Lf17/c1/'L -54o clNI NOHCNn1YYU\41,..11 R uob{\L Ai�v' - "'...- -' v^----.Cii rn Nr+AtlMntlnN\...I u6lsan\6uu4aw6u1 4°41°7+°44114,'\"1 1 Packet Page-798- 2/12/2013 11 .D. 3 . CO E.x W W p d <U NO< W N_ c.5 m ` i Z S d 1pp Z ~O n i W C F „ W WIC O Z W p n W n U W p•SI co,1'I 44 aGIHS .�qda < m 5 k-I 6'r fi m W i o W Z F W 0,Wh IOl Q3pNVd \ a 1O< 32F � Wa 2W��02 § Z� 0''0 6KZ J< [V p1 `) /j7~� "'ate & °� pO C� � m�Vy=� m V� _R rz� N N W = 7 a.4 U Za F w �° JI W H 3p gym Zp� = W*WZOO< Z mm W ' < w0 mrr 61 aW $zt,15-;w R5 0z Ma 7.1H111 r 'Z8 N NN Rc �c WW AR"'I''o< .g ''ill • W'-M' 1 O - JI- UI yN� �Y1 FZU NZO� <W S°ai�Ezz Wu-W //x,7 1 <8. J W <cl <1 U° SW N WWu.N .4< <y og y� Jd ly r .'�':.� - 6� �m K< LLJ4) (WjN FN✓='J<m re CZ ��b �i° _,°E w�y 1 CI) J N F••,z Z <p�aa <g ap 14 . J o W-'a v n Oa;? zO DO.11 w� §Ws,WWF O$ R F5 QiZ W.- 3 ~ W H 4'if m mm .► W JJ 3. c <r I ' Nt _ < S� 0 <<o«z 4a err aa.5 z 3W ^ N ' '4.556 u'a° m-0 -.5TlN ^z �?� C ® W A W C7-A cc K1 r:4z c4 d <�y� ''' I rrN O V-7`gl 1 cri lz° s�v '5'..EA N�mi I ....di a 2V U^ I O Wa 11. ! 1 1 Wp n ! mo°_ - WaS vil Q Q 'J' . ';W N W N WW� o m W O 1 p � I .: p N OII of wo°m W I i a W j m m . W ry I NUKN Y.: g if1 W^111 �I cn z WM.' I !`. ;; I x JN;; O W �1 • • `I 3Ugp '� <.i F1 V QIj y amHS 1 x° i 43AVd 1 1 I i ' n 11 J f-I / K i a II — I < ( 9 5. tV cos < Zy01'� , aJ wmo 0 0 I 1, t m• N a !,,, ,1 ahI --. ;I4 a<czi q$,1n : z N W._.W vv-iNg6W °a�I!'};I .I 4a ) <4 o + .. 6 Zp V U N '.c N "'I,r,�' ) I 3 W y'.1Iw: ' O'■Zy r WVN 1712 1�' QU' .k ii, ^2 I• .Y�I ✓�+ ��j O p,^ _ u7,, ^ Z o' {C U S L7JW Un° _ '.< N 1 YY --- 7 N QO d'al 30 _ Ian ' ,I ---'J +t a^ k _ a OQ�< K p<¢n O K H ` t`J i,'ll { I S O W '� NE I.7 8 o it ^,I t I i� ':�. .a ¢ W �WW -6i& I ,,IIm,,, , ,WZ dZJ I I t U . 3 nOtil oZ 0 a -53 <�~ , 'QO IW= m\/ Z VVmpyC WW W < 1 ! 14 EI Q '-'” ZU pJ •QS • JJ OC►ysJl g 3�7r-m-- co WWU Li�N II H W W O IpI ``'\\ I W WQ.m" Wy N >I 2 i 3 0 J r K 3g1'. I I A , , a p N< ' pl c°.' OmU Y 11!I mI i Hm4 W \Il/ RI O In 1 '6 d Nga p "' .I k iilI « Aj 4 611 m `; WI' =W . 00 j N ,W g �I I :m: Qi T a0 OW Z j A 'a0'IHS ' I W °a 1'1; I b N 9 < pp in 03AVd a� d // ] Q F I. rrr^ I .nN 1 56c.)° ■ z f iii r xU^ ( '� a e a E'N..W a ` WZ10 ��I Z $ ■ 7 J %- f79 a IS/1 6 N N Il N N •I 9p Mgp H IW/'NNp i1 (` N .i ykj` iN f W �3 3 N<X K `' i-1 ,: N z0 Z W W< 1' a W : U lJ W S X by 'i Shin f i• N W W a i 1CY 6Z:II ZIOZ/fl/II -6.P-9503 2IOHS)IO1)1pI\s15o1e0 V uold\I.A13dyS 08 3Tholor1Wl\I IJ.d\suogoes.e'ul\S1O3fOad AwayOC\WOel u612eQ\6uueam6u3 uo;Col'oaluu'1\O 1 Packet Page-799- i 2/12/2013 11 .D. i ..1 - b y. i ' ‘-:,.....„'W- ,i- r I ,---•* -i4kitiocr_. 'i'W1 ' ', - , '""-> -1 4 - 4.- C aY ,., e a r, (117911°Jiltl'id' F�° oz �.T _ , >��4 4-.f' . 1 r ;0 . 0`a.. 7 T "' .... fin-,,, ^� ' ?e� ,. a r :ae_ ' o ., r 1 Nil 3 I 1 E: . „. , *� ,. yea :- y a- III li: : a* J ,, t • 3 2 LS A �' € 1" � . L q r k t ` T$ I b 1 1 9' ' .L , ; t �s ' ; ti +� k `•b of 4 ` 1 '''f �^ O?4 Pt ,,..r. . .,„...-. -.,, s '° :$ r• o. E-• , ,..„,..,.. 8n- v f ; .• e h;r t' r } ?, . i L...,.c5 >c4, ,..._,,'•''',.r.'' : 1-5 ' LL .„, .,•. J .l .g wc,,-- — - ` Per am' � � z t mrno U � a.. 4 :v. 4 : eM 3 ... .1 . i x , ' ”' )t. r'..t an c.> + I `m u 1 ',. 4.-. L ti 4 W � .s.4 s, R 17 j k kk " ry °ri a. co i N f,. U o U N wr. / q s a KC CD W e rc� i r 4 'x S J� F \* vr p a�x eaR W S _ � 4 R-4 .ft ` , �, . {{ O°.p.w . m .*'1"....;•-: . -,tM F-,: j ■ .:err 1 0 7 _ ''• ,g . .�' ,t-...„.,- e ,- ,. ',- - - pcii.1 ,.. N. i ,,, 4.,44.7 0 . '. w u.ry I t,, p-- pa Wa ,-.e. 1.,,1 yy - A. 14-'' f• r '�° `" U z �I / c .; NO a%ry '' gds•I 1!, f F. it ' 0+ �w k< a lhN QvO2T .L.LV'Id Q cz 0 4 G 'ice �,.. _ �. ; r.t ) ' :1'3. '4' s.- t�,al b ". d:/ 4,S,- "# , - R _ F —3,---4-,-7-,-;– fi, e - eti:, _ �. A R _ ;— tt P,-- 153 w w,ant tux'.2/0-r473,>d .3..\wen.•..au uvas......."‘-'"../...."°/sr.;rana x..woxv..n"..arm.«ew wwim.,r\o ;G Q Packet Page-800- D 2/12/20 11 ' . 13 41 c° _., c0 ,trAr-1-' V,11:' 1.-: °- .':.-01'0::;-'. 0,.'.1 -,.-:1•1';',4-0, , ' 41 '-"-.R , : _ . , ,;'?, ,:.•1.v.:'1, • :: M :1 '3 .- -;:ii ,,,*4-4 :,...:' '' ,,,,...:1,,41:i.:,;k ',.4.,,i'r ''''-''' ...;:ii,t,-- ---)4,ki-,,,,Ai': ..:'4 - ....--..z,4,...,..- :1 "' .=m. tfr'1.: -'.',i*'',,, '';'1-,',, * -'!,:---',' '', ir...ik';•':,.'7 --7-1- .,• .• .j'•.i,,,..,-' ' --f . - ' 11 14 !-4......, '''''..,3 '',,M.- , -,= ,- 1 i H. .,..— ''''Li It ...,--"-!.41. .'441,1".., -„„-,. ' w I ' ---, ; It'' ' I. si, ' . '' 1 fife s,1 ; '41tc;,,,,,zi' ' ".'4 ,N -—1".' ,,,,,.:.-:-.' ;:711.,..1.,., , 4,---„It...-.4.,... 1,, 4, '''' 4-.--.- (4,1 - s ' ,..,,,,644,,,,,,...4._ `4,: i 1 ', 4.4!;'.-•',. ', k.l.q..:#4' _ • "'",,;:,,,, .t, ,, ,,, .;'," ::41-'\ lti"A'C',i,..1,.l..,„,,.:,ti41.. $,,.: ill, ' 7007,tt.,0„..-',„4<-47-17,.. ',.,..i....1.*.f , ,,,"tx,-1., '.". .'';',1.-,177,7,4,::,„.. ..,:.„:,'.., 4 . ';''''.5.'/■::''). a' \ ' 3 i- il';'''',..i,`''',Kriz'''''''''''''45;114'' 3,Zt. g,,r4,,'3,';',,,,'Al`'''' ',;;',' ,,,ip,,:,• 1!:,.,.:„,''' , ,:',r,f,;'''';',,'4,4,;.4.i';'',''''' '° '' '''''''';',•..;'3,,t4,'1-::.*s.1,'.'tg&T'' 8 10,•"', ';''3'''''4,,t°''''•,' *31,-,'. ,1:4,t.,,lii3O''5''''':1 ''' -:*.fA:41:‘,§1_0.:-;;10 3'4. '44'''t.'-',,7.;',7;;;'-v:-::: -I- • -' f. ,4'',,t- .,'4,,,--•;.i ,::.,,,e, :,,,,,;,,,,:,.;,.!44 -..-4i.4.:.-7: ,s,,::..., :,'4,',,.'f,,1 ,,,,4,4:444-.:,4''.,.i-;..ii,g4.3..:;,":'t --,1 4N44'4:4;-,,,,1*,,-- - --:.'i4:', -..,1 i,-.0,4, '',,A . ,,;tp.-&,.,,..,"-',.4-:-'1,..44 , -,' '''', • ,..1■,, 1 "**I'r*balt62": g 4 E"" ,f.-4-,.,.. -,,,,,,, „ t.l.'r','...,,g,,..t,--.),1 -1?:17y,r?....,'-''''..7i 'IA t-'31.,' ' `,:,,' '114;'":7,''' 'AiAittit,;••:' re ZI W ' 'i il: ', , li-...c,-', ''k..,!i, ---...447‘..!44..-:, .A-14 ..q; -,,, ,.■, , - .. e.o —1 = , , , '1‘,,,4 Ag„ . 4,-: ,'_e-,,,, ' • t r,;•', ' 4:k-r-,,Ives,,ililzp,7 ,,., 41,1a, -;-'-',(..t,,,,, '''IN-,' :',..,-;,-;:.,?0--,* ..0„1, ,.„.„ev,,o,:;'; „.','-x. . , .,'-t.si,At",,Sfit,,,,tt :-'f,'" r7.1 .-.;-- I,tut.,.t--er .-- ,..,. !;:i!4:4 V.ZiitriA!**,' ,''-',°';->,-.A: 1 :".1'.0:,',,,obev,i*,14 ai,-, . c4,,, ,,it,...„----'„,,,,,, : ,:.:.:-.+,•., .;:..'F.!, . ',4.47v - .4.. ,.4",'" ' .''Z'Z',- *',-''-'4;1,44-'-', z --"I ._1 -,,,,:* :,,s'..f),', "11":.';'... '-',', ;;,,,,.. .t., ....f,e40.11,! Aft*: ;`," '-''''' 7"'.,:e.I.:--it,;;'41'. C.-...1 s4 8." 0,— Lv,,,,-.:.-..:,A,;*_',,:.:-.-_,-; ,! 14- , ..,1,5.1,..,-.7.:1,:f.,-;,,,,:itlii.4,,f,;' - 1,..,:f;;;,,,....,f4c.,:i, ,,,,.-;::, . ,,,,,i,T,L8 ntR''' Ni,.:-,:-s':.. fil4,-xr 47 :' ',:.:1,.:141-4.1 5. ':',..61,--,,,F'..L-,41,-,7,4,..,,,i.,,,,..„7, , . Cl) $ . • '.,.: 4,-. ,.,,-,...ii. .,-:,..,:::',,,L,,,,..f, ' .7'.14,...,i.5.;,,., ";:',':-,, ,,ti.,:,,„ ,,•,....,,,,;i ,,,-:;,, i...,. ..„:,-,..,,, li :-..;..-:?`..- _- „,,',,i i:...i,,.-: '.., 'I,. ..,,,,,,tik i['' :,, - -.1.;.."-F!,-r..-44 ..dt..?';',:i*P. i c? -• mt;:b 47*... ,', f' PIK;'...-, 4-1:Zif 4' i ,,,;,,,iix. .211.:.. -, • , _ 1.',,,pdf.i.,,7,,„,,,,,,,,.4.',=-' ,4.•.›..:.$4, I co , .. .',9,- , ,1:- •';-,i..„,,,a,4„,%:1,,,t-,,o,i , ,„--.77.,,' •" -'' - ''''''''-xx.':',- .+f• 'i''•'•, ..Q,‘c`:•••,- ',1%'•,.•.,N,-I .• ,r4''•'..;:14,14, 1,4, • . ,,,•,. .--„-tr,,',••••• :..e,- ,o••••.i„,•,7".',:-..i.• *- -:L, F • •til,4:•,,t'-t.:'..,,,,,, !4',"r':', !.•-•,0,-, i p:4;-,e, .,,,,..„,H,,,...=,. ,..., ,-•.9;,•' ,•••••,, ,..,,-,01,14t ',•;,!•'j,4,-,-,.z. , '":„i,th,'•:gt,,l';`:?.Ver,'0',.'-'-':!-...-4-.,:,.."-';! , '• 4,;,,. -',i!..!--.',440.--*'..- , i. -..!', . - -,.,..,1,5fA,,-,;;, 1---;,, 4.*r7...''', 4:::—,,,, , C) * '' ' ''''''Is"-;'''''/'si I I"'''• ') 't*iliC't.'i..160WS, ta' 4. .. ,. ,, . .4,‘ - a mi*',,---'''',:,44's .....'- co A. ..4.h. ..,,,,t, .,,' ,, , ,...• - .A.-.1,,,,,i-,7..-At.:,-,00,,, .:1' g 02 ;., ' •".`-'9';‘`4,g- i''''' I I, f. :' ',,5--4;7.1,-. '- ,;' = -,. .,A41-e:,....1,140.-.-#-...-" eC P -a ,n4,',,,',1.*;1-,:,,4„,:-_-;;;-", ':',..;;:,,;i::: i'',.',; , ,e1r.a;',,,,,,,,,,, •E g g . v ,..:„::*.., ‘,.,', ..%.4', 7.. Li, ,,,,,\ - ., _:1,-.',Ifitr '4,;.1:7;13 , 1-'d Sko .' L . r !1.1.$:!•..-. j.,.site..;-;;,;,...,:-."' ' .-' ,,:.,. .--'', "("'.'I-,!,If I! ,I,--.:.1''. ---,'"4,---,,'''G' .-,-t-: `f--E,:,„ ,, ,, - 7.4. ,,f, ....t'34 4';',„1.-,,,. . ,,, ,...1,,,,,,,41., i • ,. :::17,3, = §a -Jr- : r- - - ''' -- ,,',,,.'i,'.--." ' 4,,..:1,-'--:9c', ' !. '=----•: ::-;-. . *,',,,tv:,;,,,,i.i.:,;-., -.c; . .,;.::„.!,., ,' ,', ;:,: , '4--, ,t, .,-**;‘,i,-.; „,,„„k:, .,.i,,- - i.,,,,1-,..-c.,:rks7-.,.: ;1 1 .:..-'1''.::3';' t.,-,1* Eg g 2 I .i'''',.' --ipf ,',..- --"-.7:- - iti!;::::,$,,,i;,' 7'...'-,4-• At::::*,.--.:- :FL.,.....!--?..ikl‘a.1 p re.;11 ' :A. . ,!-'0 ' 3 ' 1'''': ',.' .4t.-:::,..:1"•, : :,-:-° r--,... ,-:::,*.',',.Z'Fi.,.. 1.;1:::::';',,,,i,4,,q. .' ,1 9 11,73 4 Q ..t,,,, '',.iq,,..,.',''',,,,'' S 1 „ .;.:1‘''.2,.‘,,4,; '5". ; 'I.'''':'; '- '-'i;,;:i‘tt'ir.'1.# R ir,.. 4°,i0 - aii, ,'-.-.--r,„;.t ,4 .- - ,,,'''''',-'' ‘,....,:li-5 '.-:,,,.'!•!,,I.,'''';:.t: „ n.. .. ,,,:,,,, r.4.7**-' .------' ...-:„,,,, ' -- I. ,,,ifl ,1&,'!!''''' AiAtt .",,i`.', —'*:;,;''.:. '-' .-'''”-,", - c,,,,,,,,, .,.,..l...' ., . 1 ,-,7..,,,,,,,-. ,,,,,. 's -.i.,',4.e.t.'"?,,. ,,;, - .,.,-- .:'4,‘..':: . .',/';".)7'1:4:;.`i.'"i:Z;ke: '11;.:*"1"!';'A*": -,,,...-,,i011,0:,::;47:7;...:.'' ,-'''','": ',1,,,,,: .,' ,,,..`!:,,,I.;: ■4.3,-.:*:!".,:4.01.- „si-it.,,,,' . 1 g ,,,,Z:..,.t.,,'4: .1, , :'s,T14: ,...4;:,.::.„„; ...„4:4-.;,t,,,,,„ 47 t,„.1,..,;i.- 4'-f.t: ,. .'..-:''i?: ,'''l a:--:-,i'',:'..i:f.•:::::'.-4-..i;'. . lal i 1 1 .T.:.;.7-::'-,' ... q .::.-'.):::, 1.44 ' i.''' .,;:: ;AI- -,,,...',7,-; 771"-z,;- 1:-.4 l'.(,,.. 1,.ti4t-.z:4471,4-‘-:.-, k-7p4ik:.:1',. •{,1,7-4,4- :..--:, ,t-r,-;','.2. ,„ 2 41 .. ,".,, .,,.:-s!4K,..,,i,A,:,,;, :,.g.,1,,.. a c-'a-r ., ,..,,.,;„..‘.,„. ,, „,,,,r,..,... ,.. .!.;•,.s., ,-,-4kA,1*;,- --"' ' ',/ ''' :5445,4 I".'-N 4''1 7'44,5i:;k1:524A 4,t t.':4;.4.Z1,1,''''';5'''';4::t';*; ''j5■S :i....ta':'.'4 '5'''':. L '05 '1' AZ't,'R'4S;5i115*1':rfl5::'"':''':''.'"i'''':471' Z:`'2 i' 10f:11".'';' .'''P',4...15,7'7'''''' '''C -*'4,:.:,*:*''4..)4.4,:.:7:1-,,„ ' ' -'?,, ' t4.1:1;1'f'''.41t14;.`St..14... .''''4:•4;.•';''';' E E g!i i A,1,.. !I , `.;.., ,,,i1,,,fx."I ',,,','. 3 ,,,) ';'4.:,,,,,o,.,,,,s';■;:7" % ,. .''''',* ';*'' '..,,;T. I.? -.', ' ;-'• ',1, ' 4-.'7*, .. 4.4.417,..k'41 au •,,,...''''r,,,.*4',' I '4,4f.,--' 1 -- #-e-FA': - e'''. ■` a ';':;,-'03''''.'''tf'".1,..4,:t-,51.Ntilt'''„?.,, °' --- ft 14. :- ■501‘e,"-"t',*/ /N., -:*,,* ' '7.',"-...-: - TIC:4'''''',*f' ` - *4. ^. ''' -`*,.,' '1 W '-.;,.., \ , .,..t.,..,,-4...;.2. :;,,, .: ,.t..?,..,,,,',,,,,,..,„. .37.,*-L., *-., ,,- ....7'...0T''''':- ''• -:, T.' ' 1° ...,:,:st, '. , ,....a - ,,' .. -.'.7,,,,,,,,,-4,-.:!::: ,•=' , ,,, -tr•,,,,:.':.-, ,-,.,, ',,A , ,,,,,,4. W.i.e:A-4-..—,* , ' •'' -'i',- ---=- -...•'-4 -.4.--, , c,r 2k-.-' sa'.-5 .,.Akpon.sc'''-----,.-'-•' ' ,-- , , .: d„,* . '4,0'..--'—'....,,,/ '.,,r; 1 .\ '.(;:-.. •--,•-•. .,: .r.,....,'" N; .- .. ,-,',...,..g,•', . .. ,,.- , .`.?3-)7i4'\-4", ' .S*;•: ':=,',.",,,,*,::Z,..k'.--,''' g .,„,...,-., .-4.- :,, 4-,0--oft: ,;5--- — - w-. - - - - - — - '''--;',t''''':-‘,.-."-'1'• 4'''''. - . , ■---,,,- t.,, .--4.0, .-,' - ,--,..,-t-'',t 4%mb,41.%!"'...-. '!-,..-- „ '-;,-,*2., '4i'-','.•:`,• 1,'..t.k;':;,,.::°v' , ,q?---',9 ,," ,-.',L7..\.34-:'---,---4, ', ',.....;.:. *..Z.', `-.-vY-.' - .," '4',7 ',.:i,,, IT41!„,''''', 4! ■ ' ..,-,i,.k‘ ..v,..:'''':'+':-','Aitg.,'" :- -‘.,,_.., .-,, ,,,,,,..,..Z:' -' :t . ::,,,r,v),,,r; ;"',Z",• .."' \ .'. .',',,,, '' '' '''' ' I<ir--;71.1 . ■ V'2;1'4 E''/,‘-- '-<, A i'`,,,. 4%1`,-.". b '' ' . ';1,•'''''. \.„,.....3- '''', , ',„.;,,,'.Ar:„!■*1 .,'-::,,„ -,,;',..t..,-;;V; 4.-f-t 4,, ,--t f ,, ,,: ,s..„„ , ,. , ----z- ,. _ , ' -',...,,L,.,.-,,, ,,'.A•.4,."- a.-,-! -,,tq!‘,...', ,'-A,L, ,,,,„--- Nr„.,:t, ,,„ ..... lit . ,„ Packet Page -801- 2/12/2013 11 .D. . -,• 47.4,7.:"4:iiii•-•. r.-14,44.. ,',.' le,-7"7,-- .i1;•.`,. : .: .,1,4 ..,0",,.... . 5 \a„, nd 7g, A .. j.•r .Zftk ��' .,,,.' s•:.i.,W-' a�°AR[' x iii 8 •" `� i. i ' --...i.4 iIGIB °y ' � z y �-m , , -.r ke - ► L i ;3 N�,.:-.7,--1 t3 I Ir r114;,-, .: ; lr N a a2 �� F c. any • ,gg. + .1 3 O_ H ••. '' t"'"-,■ • .' ',t,-- ,'`. ''• •• s H err x . ` • iw W x°n W o xr 4 • 2 I i M t - 1. 6i I_ L s I ,,z t a ' ' .. io-� i 3 t �� x �• r. y • \�Nth. � ay" m' °� w q m t' ,r,t � x �, 9 �- .[ , V [:ri+. fy,i i.---,-,{�., g• qtr r«-,I• r xp, y�-• tip, T 1 dd N , l I .Y' � s,,ao• 9.4 `-It'-' . l e `r Spy'V 1 ''4s''q N x a - .y0, r g Cm_w , f \ S. nn , w .,4Y.S J�rtr , k 1 �y O$ V.I , . �V y J �.. 'AMA K`yi M ��yl, 1 -*s. E N - O W w?.3 � ... .,W ,Kn 1 _ #+rq •z '°•t- raj. .1 4Y"I ! Q.`.7• I ,;:k.,7,4..,%;:.,,,,,,-A . ' 1 N ,' '�1�r�'�1 .{y III- �.�' Y,- OV tV 1 . , 1 1 • i4`,""w' ; y, i? ?" - -i r 'r `x.1+1 _•:.•' 4 ~� l . i.t d �.ty � . , 4,C dy ' " 1 R y `.Sa '1'• x 40$ ' „ ..a 1 - r,� i 0 - +k4 Packet Page-802- • 2/12/2013 11 .D. Q 0 ......1 • ,•t k� r ,, d 3 -..A r p e r.'et.ff-' , -1_• A'l': . i 'it/... • n V o� .� 'f , I I" ay. `i 'w ' Ai• gi� '�`•"ks 4 ! ' a r�r ;. d gp t . i •' s S.' at s { 'y ti Y � w w ." t '' %*"' . � �. R � a a r v .0 Y i .. ,? `� -w ( I:— _r.' +`,4. . � r::a, 4 3 r F., .- s g 8] d ,, `.r Ex t 2• : c?.: s •,44.... ,l.k �t 1 1,1= �w. .,,Ati H fi•.. .rte a°'k . L ,I [ 'cr., ,r E.E. • ' W . .[ Ag ra; I R i �R .t aA:K k.. I a k 3u I- ui i3 .ice' i .' .i.# r .IR. as• i ': d W r ,I,• viQ � ` ^w w• I J i s e-yam 4 ' �I ' ! w 'Fr '1 l'-.9 8 • 1 L -f T .,t t J - t J. C.]q 4 cd ar�*.� -_,;1� f-•7 �-`r w o�- vp�u a cn t s_ -`.. ..i,. i; , �; fi r+� �.:�'4R�. Z vwi�o: aSt a sibs ': y � - L y` a O�o�• R• p 1 °: I r4a � 's� yy aP 1 j ; yyi;tra a ,,4s.. _ o r u a. ` sr+'. ry '.. Y 1 rr j1 .n ate, M ,Ni -:� �ir'7 r• I A OSi w • I :.. fit ' . : �, L ,' v-,r� r. . " . . cam ' a su - g. 6 aw. .ram 1 } P or"� 5 lr � . \,7 ' t i ° 1Y",.. : -' 'i -ram .y U o• ,. n i �. mac, ad a I ,.,1t 11,-.4%.17.-4z.. .. .c._ wry, fi.r_r 'R � ��' m' � f 1 �,-�d� �� ,�. ,; 7'k'ryc f` "' .y r"" { �`� '� 1. Y' _j i r wi 1 a', '� w 7 :L.,c a, x.: rdp ;L.'. S sir.` I L x,:M b ,1 ,>�• T t.zi.. , , ; .a �+5 ! v p x d :3 -9f In .a+i""!a,1'a :... ems. { ! 7 i yt ;1 - ,�:` : x a r � y9 § 444<1 tir °1 �f . Packet Page-803- 2/12/2013 11 .D. .A,r.Fx ,-• , d� �—-NIL ,-1 � w�.. n 1 9 i 4' .YCC $ J' - 6,, � }' e A,s .i '4..'44,'. -1L,? ;- ' 5 to 1 0 7 a 4 E Y+ � ;4 ,: Qt 1 1 4+F t i - gg e E� �i 9 1 j ar �1;'_s € . .�'b, • '..':,' y+. a „ '. 4 ` g !�Yw. , m�,. a mot#t, x i .. , a A r"a �re , v"+ '41 Ct�' r r � " r• a ''ka sC- S. A ,',..,,i„. _g, Vie .y n * . i i f �, P n£ „r a '' ,W'4, ,ai a. 7 a 4��'� � V Q a ' ',. .,44,,,:,1,. �� e i ,� f ''''.4&,,,r,,a+ 33 ro x m b w' M e ` i1`'ro,u fi+k�•t i l � b-,t,... -x� •v s qi I l I i^` @ c t•' , S '4, I t 5f �i } }} cn� �a,' y ,, ,a ya , e' „ ,..4., 4R �� r a, CI aI ' a 4 , il ,., , �1 c 11 r l�, W `s i . r I s,,,, � t om� , c yS � ,pr" ` a i i w ,r..;.]a.,e pp t:.� s 1 „y R ' r°o a ^ m» � o I -, y O c.; .a u ” . a 4 '-‘174i,,, w �is, i 4 s,eF, k 7,,t;,-4„:„,,,,:,,,,,'?: � µ :1,71:;,,:7'„� � �. 4 ��x�' •' l`v EC 4:- o � c : f a ' 'f g . .p 1 d � i�7 .,M r * *y��d i 4 `'--ii .w > rt, a �"CF ° v 2 M a I * �� .t q 8 z bll s 1z�`'a # a �; 1 'k ',,ti rW tea Y ,py y . 4 g �.. Q' � 3 °, i �c x � 4 qt�•Y4r# �`a7� `� � „` '' . � m'� m t�� , ; $ r ��t� ''''..x„'ss R -M' 4 ' m �. h `ce”, ` % . ..w 1 ,' ky'i 1 P� 1 n f rh ++7 i . " 4 a- arP 1� ' 3bV ) 1 %aP a t � "0 ' '' I �. rl S s s � . „ c ..y" Y ', W i .:.4 .B x °' ''� 7 , `„ tP ' .,* 1 - 4. ¢ � a s °ra ` ''y„ 1,1 I. 1 e r :#,'�, h i 1 �NtlS ` ",ya`.6 a:a 1 QVH AT / ,(N id a 'v p ,y ° r ,„,,S i ' aes '� . y b p } ' . � r� � 1 ' � . 04-' �'' - & h a � ,� 8s"', �"` Page-, -' s \ a !, At ke-� ' a Pact„ b; aa mo $K :M ' k'1,,74.;''''' 2/12/2013 11 .D. .� - � z � � ` � W taY ?'�• db . . � �� '' ,. i : of "�` �i ' � 2 wa.� o�� r ya ? y x e'<al S'�f�` ytlA y..; ....,-- , cil d `�� r "' a � iii Ew '"�ti i q k.. >. z t i1is ,-,...,2, A`" c ` a ' z •�` r Y � ... 7 agQpg9p 1arcd`.:.wd- w I 4 ' a �' �j' err 4 � l+ r, hC < ID Yfr a",YI+" O Ir--J, 1�* y L;=" 0 d' ,�. � �":� xaa° qy".4 co 1� a `. Pr AA 1 � 4 0 ,y, 'Yr ? i 'J --u '07 Q it..,". a�. .mN WY mmE-9-,--7iil g till' w�k 1 a�ci� J o�z . � \ q o ` ., 1 'yam . a m axyp."�.{; g .,' E � ti c, . Tr x f*"A � a� iE '''';-':*47:4k-,1 tom. �$ 7 O II m s � '!.t z z a z( V S3 dd & I 'n(,3 i1' t2`"'z '` 8,egg e9G ray'� § P pY 1 3i vw,Z r - ot�iS =1 :�a a � y f,'''',' . 'iir��yy. g 5 `,,3` �� .i s'� ' so u..: r -�"cxa. p, u PG f } *lfa ' :1 Ys Lk.4 r r - , ? 'v �r•, .,...+�,a` .' r °,_'-':'.} R : -,... ..,....,„,.. Y Packet Page-805- 2/12/2013 11 .D. ® m �: i ,sue. � � � � i � � 1 �. l .. '1„,...:;,,t/,. L�i44 qQ s i�� ii ....fib hd" y6� 1'-r�e^� 5 ��' 11� f �t S'6„py 4 Ga ! ',4;,>, a. tea, ,nn t t . e 2 r r ° & n < i iLi a.1, 1 , -sit aI � 3# M d /1xx Nw � �! p3 aw, k r -z"..`;-;, -'�§ It' y„ 4% '4I-' t— I 1,:i o .�� "'4 = '°'g�u.„''',;,, .' i .,'044,4i,:fi*.i.;;;',,,' �� h.- , as` � � � x � 1 t �` I �� &1 „9 "' K>;r{tia° ar x� as (� .1- u r t y ,,...4k;;, a' �. ?�i "t rah t s-jyy. "� ,: ��` 6 `' - ,, .T1ii•riz � m L *06F 1-,,tel:4,*„ : .' ''';''''':);-',;44:!; ,'' 1::;''CO Q r 4 I x{O �,7vk 'f.1%,(4.07'.' '.,'..?,44*: � � --r a t $ F, v C N -1111 - '. `0°.,-144,kJ< :1'3 9 F-. � M -4-7,-it; tx� Fq � � i:; �Cl� y ry _ s I � ,.,,,.. F4'' (4'..,,,i,:-.;,;'0,,lif' i'' 0-t,1,, --t. ,,,-iz441:,,, ,,,,, ,..„..,..„.: ,,,:,,.,,:,,., 'f. �{� 1rF „z � r� r �� . ♦ _ p _ ,,,,,,„...,„,, .,, -74, : , (I ate , B a'� .� 3°�s i �. "� 9 wa o r �t` ,a'a'a` y,a; `'t; ` �'`a e �''t . '.. I=n ao.<. ! !JI $ p g n k r & Y Ifff , a W WN ' cr d .$ ' "LXit, a ,,.' WN'nx II sk i - t I why a �... '4 v „"� 1 1 i &Z^''N°LL E Z a 1" itl' �. a yy. ,ap 'FY tt ,---''''':,,,'VI r _ a � dq W.- r*' xy _ ?� ".� »rd ate#., d° �'tlV I , . , .. l s�>i',7,, . �, r IIITTT�111 Yttt o$ . c„iil*::,.. 41?--- ' t 1 nd LZ Z ZIOZ/ol/ZI-6w4"G,u fl E'-'d tlONSMOnnI\e�1o=a(]�P u^'”• •••••-•••,^,•••••••"„"'n.�.n��eue=ul\51�3F'0l1d AYMWOiI�uway u6no0\6uimaui6u3.oI1 d.Fn,L\' t'®d Packet Page-806- 2/12/2013 11 .D. Ai#Ikl- "c 4, m W N,- E- .' aO h �`i$ o O W wi g20 ya 3d X+ O . a a v g 'a p fit 9 :f S � Q 9 :� 5'fif C d 9, 44 ffi$ a 5 z, xY' Y`T tk t i , A 3 Z r�T dA 7 `, �" "y: " ,S c4 O W 4# i % h' ' d k ‘1j ° W°�: Y wm S O (v' 1 �amow . 5 Al w O \ N Qy ' rtQ m4w � �JQ n 3 a .i W a 2 Ew x ik g Em W x 1 Si WQ.w =W= F ri CC cn ..;' cwY F 11 Z W 1§a N 2 A . f W m F tr ,.., ,„„. , , , w" mV t! f kzR ? m d r° ti xqx o ca, K i 1 9 ey wo„ y� X O o.i i',lig'.. ,t-_ _Nd sY B9Z a I/Z,L r-�x F - �3 F`��tr,-,.1 ° H-y, I ,6 i. I rc I fi e 4 til I a dpi• "4 8* v �" x0 9 t,gill a < r ompl m n x w0 ti N w+ ee w N © I w• Rs A id a _ 6 g . g n p oc ! m 3~a f nom a n' a N w Oeuw\-° f, H , 15 70Y ul6in uomss wO\us.3 l u6tl\ws Od AVN w!l..olul\51730llNNI\lAA'3ND807-ON Ne-3tlA1- I ke�O A ct PagaI\axPd tlOHNON1/fles,t LIOZIO !II W In li I i i 2/12/2013 11 .D. ▪ti w 1 C 3,,,,,:-.., ',...,,tn:44,-,,,.:" � rah � ,' * • �$ u ,' f- r: k � , � ID■ �.� �'ais� . r +r a .0 - ea '4`1'...,--:,.: '` tv ( aYiy t kr ,d ,., rt��.,y.4�'J w �� .€r r !dam i i a {- I ��.,*s i � `€aye F � �,< a`� �� Y�� ,. .,�: -.w.� �1�� !i9 . ; , n, }4� � fi r a� „y 4 I ff > .ry 9 i�i 4zk 7 "r ,x„ .. ;{ � �' :� t�`+d� � " y��j/a tj ?S �,2't' J ' As ' 't.-.. �r 2'f, af. t � ,h a "', s.,T"a ?N' . , , I �V ,i m t"'ai 1 4A,,( �`" 4-,,..,,,,,,,L,.,,,,-....,,,:,,.,..',:,,,,,,:,,,,,. �f f� k .� ,,y ,1,'„:',4,-;4'-:-. iC Y ^44 1 4: '1 ,4 t7 VI m ... _ �,y� PY� 7 � y�ir4 ;'�# `M��,��'. �'LL"�0.� y,��v � ,k ��,: I � t�yf � �� > W �h, I 7 F r '� � � a' i r F+-I f � D ` . 'Ar^ , ,- dam' �,�L.: }, 9�r `.. G __- i it ' U " ,e ca m I' c� , rrO�� fi., e«C d e -« y ' '.,.t a .1, x� a € W Z r4 �'a '� Nom, SrF""4 h f r+r� „,,,,,-, ;, - , • O .E,.m 9� �d �I_ � vkc�zwc� 5a3 °�� .,� �� t � � g. �, I. O t� � �a WYw°�'Y _ ea c c4 %,,. €' �_a ,:a g € .'y a` ,q i, ', a :"":'$' ''a ^% ,M `' E ^” N p< CO `rr'^-31 d K W f- 'w" '�i Z 3 N 1,3 j m �.., ' € a ca s y'. t t ^ ski, I U p ter! [[xx]] e� '4 , p' ..7 4 ay ,;- E t >y s - i fir; �� rr .,m.. .. � £ I P � v �U FAF--t � 1 k t. .� rg `f„" 1 .w Ft x,. nog 3 $ -x N 3 f3" Pti Q •, au.� .� �� £. i � � srb y Y � t 3 � y,+e. '.. 0-0+aa pqq• a "tea ° i i a V„.,,,",*".7:74-:* l'F U I g�yy �k,�y,�� ' y: n, xe� \' a at �e r ,t .4 � I,. ,. � ' k I 4e. � { ., . F r 'I '6 L rte. le 1•"L � s } , +t. c a t'+ a s"s '4-1',' 4'�` mw a. .1444'1.'-'..lit''';x„` 121b1; y.u. M ,4 h t -:,,?,#„;,,s,,,,, - ,-;;; -='=,-1''..2,''',',.ti -.'--, ;, -,*,,,, .; '' ' �- ti;‘,4,-1.1'.,:r.r, a � 9 d f'. auk � �� s fig' , ,.. r,-; e "Hi',,a �` �' a�ww7�rrs g�`�yE' �' ..4-:,.,� t, ;:...;-:-',4-,',',4,;-"€ y ' I -a "� � y g 41 � a'4 ' „3`7^':' A .. .v ki,- r " r 4 st- "' i n t I '. °cz c� Yet a x ° a � mow£_, _ ,., y .€. a ,. .. xt: a aEc gi- yid/0:y SIOL/Ol/Ll-br.o'$T3tl 91 Slld tlOHS>ON \e! 9;gnu\t it�,re nu]7Trvnwwl\1I J\nuoq�ey)ul\Si 3'Oad AYMOVOtl\u°°1 u6mep\6u1,»u!6u3 uoi4oWmuwl\:, Packet Page-808- 2/12/2013 11 .D. ® m .'.`E._g „ x bs i P y r'' e'# ''�'s . C.: E.+o-.:$� `s a � -'-: €<s`r,;'E f'.f°.e1l•? t ;te..�a,° ,,..„--,-,, ,..,,, \6 is ; �� i w K _ I''r ' �, rrr'4; a i i i. .srµ i ,.,:c ..,k B J of w >.` -a a. :is d 1';, '' { ,,,, a F 3 >I mom,r ., 1 , + U I ow v k m. q tor Y i t ' { a a K U .wM• . < -2'A==.rs , � 1 W ¢ , ._-1. O x S C''''*„:';',;,,:',:.;-:'1”' ' � ' •} w< 3 Wo "a� 2 ; � � e I O rwagz P o s� '� zw• at � -r a#. I �c°i'-'., - ,,,,,,,, , tr. '4!".:.''',7I'`4,4 . ' il,11‘ .i ,5,—,e ' � z Ott t., f ,�j't a „ Z° - v g4 ot , ' `trf .,� !?,::,4'.)^"! g te . �m � a fir ate Cs 't, X08' � �� - U x Y ss a f 17:71.,.;-.'-`,,',.,':,i1 k " ;k �P 3 sX s °` �� . U W ha 9 2 ik < v - P. .? 6 '4,.e ''''1.15V,.1 - 1�" I s# 'wr a�' 1 £r Ni ise mo 2 n y .. s� � s=r1',,,,;."*I #i r * ..1:�A` 1 +:' Pte t i a d-'a M1� y d ' t' r% ` a �� + i * d c� i k.. .. d" y . I z' V i I Q '-- ; *, � S£ .� z,, k,� i y t�n + °le ; z ' C . ! 8 3 1 .6..0\u.wu ' uo :4+ . c t c 44. 4 M P'...1.:;,::'Z':i,'"'j.4.1„-;:t.:111,- -,,,,,, ,,...,--i-A-,7'.- # � 4 w eo \, # ®6 6u3 mro' a „. 6, x 9 Q91 oauu\c��pi , wAiI as� re t �� ^ rwe-809-�� ket Pag ad A9 l$OrvwI\'I^e0 PacaSo 6 vS?a 9l ,1(LIZ ZlOZ/61/ZI?la ,I. , 2/12/2013 11 .D. TABLE OF CONTENTS PUBLIC NOTICE 3 PART B - INSTRUCTIONS TO BIDDERS 5 CONSTRUCTION BID 13 BID SCHEDULE 14 MATERIAL MANUFACTURERS 15 LIST OF MAJOR SUBCONTRACTORS 16 STATEMENT OF EXPERIENCE OF BIDDER 18 TRENCH SAFETY ACT 19 AFFIDAVIT FOR CLAIMING STATUS AS A LOCAL BUSINESS 20 IMMIGRATION LAW AFFIDAVIT CERTIFICATION 21 COLLIER COUNTY SOLICITATIONS SUBSTITUTE W—9 22 BID BOND 26 BIDDERS CHECK LIST 27 CONSTRUCTION AGREEMENT 28 EXHIBIT A 1: PUBLIC PAYMENT BOND 35 EXHIBIT A 2: PUBLIC PERFORMANCE BOND 38 EXHIBIT B: INSURANCE REQUIREMENTS 41 EXHIBIT C: RELEASE AND AFFIDAVIT FORM 45 EXHIBIT D: FORM OF CONTRACT APPLICATION FOR PAYMENT 46 EXHIBIT E: CHANGE ORDER 49 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION 50 EXHIBIT G: FINAL PAYMENT CHECKLIST 52 EXHIBIT H: GENERAL TERMS AND CONDITIONS 53 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS 79 EXHIBIT J: TECHNICAL SPECIFICATIONS 80 EXHIBIT K: PERMITS 81 EXHIBIT L: STANDARD DETAILS 82 EXHIBIT M: PLANS AND SPECIFICATIONS 83 EXHIBIT N: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT 84 2 12-5948R Immokalee Rd Paved Shoulders Packet Page-810- 2/12/2013 11 .D. C,ol r Count Services on Purchasing PUBLIC NOTICE INVITATION TO BID Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160) COUNTY BID NO. 12-5948R Separate sealed bids for the construction of Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160), addressed to Ms. Joanne Markiewicz, Interim Purchasing Director, will be received at the Collier County Government, Purchasing Department, 3327 Tamiami Trail E, Naples, FL 34112, until 2:30 P.M. LOCAL TIME, on the 18th day of December 2012, at which time all bids will be publicly opened and read aloud. Any bids received after the time and date specified will not be accepted and shall be returned unopened to the Bidder. A non-mandatory pre-bid conference shall be held at the Purchasing Department, Conference Room A, at 10:00 a.m. LOCAL TIME on the 5th day of December 2012, at which time all prospective Bidders may have questions answered regarding the Bidding Documents for this Project. Sealed envelopes containing bids shall be marked or endorsed "Bid for Collier County Government, Collier County, Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160), Bid No. 12-5948R and Bid Date of December 18, 2012. No bid shall be considered unless it is made on an unaltered Bid form which is included in the Bidding Documents. The Bid Schedule shall be removed from the Bidding Documents prior to submittal. One contract will be awarded for all Work. Bidding Documents may be examined on the Collier County Purchasing Department E-Procurement website: www.colliergov.net/bid. Copies of the Bidding Documents may be obtained only from the denoted website. Bidding Documents obtained from sources other than the Collier County Purchasing Department website may not be accurate or current. Each bid shall be accompanied by a certified or cashier's check or a Bid Bond in an amount not less than five percent (5%) of the total Bid to be retained as liquidated damages in the event the Successful Bidder fails to execute the Agreement and file the required bonds and insurance within ten (10) calendar days after the receipt of the Notice of Award. The Successful Bidder acknowledges and agrees that it shall execute the Agreement in the form attached hereto and incorporated herein. The Successful Bidder shall be required to furnish the necessary Payment and Performance Bonds, as prescribed in the General Conditions of the Contract 3 12-5948R Immokalee Rd Paved Shoulders Packet Page-811- 2/12/2013 11 .D. Documents. All Bid Bonds, Payment and Performance Bonds, Insurance Contracts and Certificates of Insurance shall be either executed by or countersigned by a licensed resident agent of the surety or insurance company having its place of business in the State of Florida. Further, the said surety or insurance company shall be duly licensed and qualified to do business in the State of Florida. Attorneys-in-fact that sign Bid Bonds or Payment and Performance Bonds must file with each bond a certified and effective dated copy of their Power of Attorney. In order to perform public work, the Successful Bidder shall, as applicable, hold or obtain such contractor's and business licenses, certifications and registrations as required by State statutes and County ordinances. Before a contract will be awarded for the Work contemplated herein, the Owner shall conduct such investigations as it deems necessary to determine the performance record and ability of the apparent low Bidder to perform the size and type of work specified in the Bidding Documents. Upon request, the Bidder shall submit such information as deemed necessary by the Owner to evaluate the Bidder's qualifications. The Successful Bidder shall be required to finally complete all Work within two hundred and ten (210) calendar days from and after the Commencement Date specified in the Notice to Proceed. The Owner reserves the right to reject all Bids or any Bid not conforming to the intent and purpose of the Bidding Documents, and to postpone the award of the contract for a period of time which, however, shall not extend beyond one hundred twenty (120) days from the bid opening date without the consent of the Successful Bidder. Dated this 16th day of November 2012. BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA BY: /s/ Joanne Markiewicz Interim Purchasing and General Services Director 4 12-5948R Immokalee Rd Paved Shoulders Packet Page-812- 2/12/2013 11 .D. PART B -INSTRUCTIONS TO BIDDERS Section 1. Definitions 1.1 The term "Owner" used herein refers to the Board of County Commissioners, or its duly authorized representative. 1.2 The term "Project Manager" used herein refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. 1.3 The term "Design Professional" refers to the licensed professional engineer or architect who is in privity with the Owner for the purpose of designing and/or monitoring the construction of the project. At the Owner's discretion, any or all duties of the Design Professional referenced in the Contract Documents may be assumed at any time by the Project Manager on behalf of the Owner. Conversely, at the Owner's discretion the Project Manager may formally assign any of his/her duties specified in the Contract Documents to the Design Professional. 1.4 The term "Bidder" used herein means one who submits a bid directly to the Owner in response to this solicitation. 1.5 The term "Successful Bidder" means the lowest, qualified, responsible and responsive Bidder who is awarded the contract by the Board of County Commissioners, on the basis of the Owner's evaluation. 1.6 The term "Bidding Documents" includes the Legal Advertisement, these Instructions to Bidders, the Bid Schedule and the Contract Documents as defined in the Agreement. 1.7 The term "Bid" shall mean a completed Bid Schedule, bound in the Bidding Documents, properly signed, providing the Owner a proposed cost for providing the services required in the Bidding Documents. Section 2. Preparation of Bids 2.1 The Bids must be submitted on the standard form herein furnished by the Owner (pages 15 - 29 as bound in these Bidding Documents). By submitting a Bid, Bidder acknowledges and agrees that it shall execute the Agreement in the form attached hereto and incorporated herein. The Bidder shall complete the Bid in ink or by typewriter and shall sign the Bid correctly. Bid Schedules submitted on disk/CD shall be accompanied by a hard copy of the completed Bid Schedule which shall be signed and dated by the Bidder. The Bid may be rejected if it contains any omission, alteration of form, conditional bid or irregularities of any kind. Bids must be submitted in sealed envelopes, marked with the Bid Number, Project Name and Bid opening Date and Time, and shall be addressed to the Purchasing Department, 3327 Tamiami Trail E, Naples, FL 34112. If forwarded by mail, the sealed envelope containing the Bid must be enclosed in another sealed envelope addressed as above. Bids received at the location specified herein after the time specified for bid opening will be returned to the bidder unopened and shall not be considered. 5 12-5948R lmmokalee Rd Paved Shoulders Packet Page -813- 2/12/2013 11 .D. Section 3. Bid Deposit Requirements 3.1 No Bid shall be considered or accepted unless at the time of Bid filing the same shall be accompanied by a cashier's check, a cash bond posted with the County Clerk, a certified check payable to Owner on some bank or trust company located in the State of Florida insured by the Federal Deposit Insurance Corporation, or Bid Bond, in an amount not less than 5% of the bidder's maximum possible award (base bid plus all add alternates) (collectively referred to herein as the "Bid Deposit"). The Bid Deposit shall be retained by Owner as liquidated damages if the Successful Bidder fails to execute and deliver to Owner the unaltered Agreement, or fails to deliver the required Performance and Payment Bonds or Certificates of Insurance, all within ten (10) calendar days after receipt of the Notice of Award. Bid Bonds shall be executed by a corporate surety licensed under the laws of the State of Florida to execute such bonds, with conditions that the surety will, upon demand, forthwith make payment to Owner upon said bond. Bid Deposits of the three (3) lowest Bidders shall be held until the Agreement has been executed by the Successful Bidder and same has been delivered to Owner together with the required bonds and insurance, after which all three (3) Bid Deposits shall be returned to the respective Bidders. All other Bid Deposits shall be released within ten (10) working days of the Bid Opening. No Bid including alternates, shall be withdrawn within one hundred and twenty (120) days after the public opening thereof. If a Bid is not accepted within said time period it shall be deemed rejected and the Bid Deposit shall be returned to Bidder. In the event that the Owner awards the contract prior to the expiration of the one hundred twenty (120) day period without selecting any or all alternates, the Owner shall retain the right to subsequently award to the Successful Bidder said alternates at a later time but no later than one hundred twenty (120) days from opening, unless otherwise agreed by the Purchasing Director and the Successful Bidder. 3.2 The Successful Bidder shall execute two (2) copies of the Agreement in the form attached and deliver same to Owner within the time period noted above. The Owner shall execute all copies and return one fully executed copy of the Agreement to Successful Bidder within thirty (30) working days after receipt of the executed Agreement from Successful Bidder unless any governmental agency having funding control over the Project requires additional time, in which event the Owner shall have such additional time to execute the Agreement as may be reasonably necessary. Section 4. Right to Reject Bids 4.1 The Owner reserves the right to reject any and all Bids or to waive informalities and negotiate with the apparent lowest, qualified Bidder to such extent as may be necessary for budgetary reasons. Section 5. Signing of Bids 5.1 Bids submitted by a corporation must be executed in the corporate name by the president, a vice president, or duly authorized representative. The corporate address and state of incorporation must be shown below the signature. 6 12-5948R Immokalee Rd Paved Shoulders Packet Page -814- 2/12/2013 11 .D. 5.2 Bids by a partnership must be executed in the partnership name and signed by a general partner whose title must appear under the signature and the official address of the partnership must be shown below said signature. 5.3 If Bidder is an individual, his or her signature shall be inscribed. 5.4 If signature is by an agent or other than an officer of corporation or general partner of partnership, a properly notarized power of attorney must be submitted with the Bid. 5.5 All Bids shall have names typed or printed below all signatures. 5.6 All Bids shall state the Bidder's contractor license number. 5.7 Failure to follow the provisions of this section shall be grounds for rejecting the Bid as irregular or unauthorized. Section 6. Withdrawal of Bids Any Bid may be withdrawn at any time prior to the hour fixed in the Legal Advertisement for the opening of Bids, provided that the withdrawal is requested in writing, properly executed by the Bidder and received by Owner prior to Bid Opening. The withdrawal of a Bid will not prejudice the right of a Bidder to file a new Bid prior to the time specified for Bid opening. Section 7. Late Bids No Bid shall be accepted that fails to be submitted prior to the time specified in the Legal Advertisement. Section 8. Interpretation of Contract Documents 8.1 No interpretation of the meaning of the plans, specifications or other Bidding Documents shall be made to a Bidder orally. Any such oral or other interpretations or clarifications shall be without legal effect. All requests for interpretations or clarifications shall be in writing and addressed on the County's Online Bidding System to be given consideration. All such requests for interpretations or clarification must be received as directed in the Online Bidding System instructions and prior to the Bid opening date. Any and all such interpretations and supplemental instructions shall be in the form of written addendum which, if issued via the Online Bidding System at their respective email addresses furnished for such purposes no later than three (3) working days prior to the date fixed for the opening of Bids. Such written addenda shall be binding on. Bidder and shall become a part of the Bidding Documents. 8.2 It shall be the responsibility of each Bidder to ascertain, prior to submitting its Bid, that it has received all addenda issued and it shall acknowledge same in its Bid. 8.3 As noted in the Legal Advertisement, attendance by all bidders at the Pre-Bid Conference is non-mandatory. 7 12-5948R Immokalee Rd Paved Shoulders Packet Page-815- 2/12/2013 11 .D. Section 9. Examination of Site and Contract Documents 9.1 By executing and submitting its Bid, each Bidder certifies that it has: a. Examined all Bidding Documents thoroughly; b. Visited the site to become familiar with local conditions that may in any manner affect performance of the Work; c. Become familiar with all federal, state and local laws, ordinances, rules, and regulations affecting performance of the Work; and d. Correlated all of its observations with the requirements of the Bidding documents. No plea of ignorance of conditions or difficulties that may exist or conditions or difficulties that may be encountered in the execution of the Work pursuant to these Bidding Documents as a result of failure to make the necessary examinations and investigations shall be accepted as an excuse for any failure or omission on the part of the Successful Bidder, nor shall they be accepted as a basis for any claims whatsoever for extra compensation or for an extension of time. 9.2 The Owner will make copies of surveys and reports performed in conjunction with this Project available to any Bidder requesting them at cost; provided, however, the Owner does not warrant or represent to any Bidder either the completeness or accuracy. of any such surveys and reports. Before submitting its Bid, each Bidder shall, at its own expense, make such additional surveys and investigations as may be necessary to determine its Bid price for the performance of the Work within the terms of the Bidding Documents. This provision shall be subject to Section 2.3 of the General Conditions to the Agreement. Section 10. Material Requirements It is the intention of these Bidding Documents to identify standard materials. When space is provided on the Bid Schedule, Bidders shall specify the materials which they propose to use in the Project. The Owner may declare any Bid non-responsive or irregular if such materials are not specifically named by Bidder. Section 11. Bid Quantities 11.1 Quantities given in the Bid Schedule, while estimated from the best information available, are approximate only. Payment for unit price items shall be based on the actual number of units installed for the Work. Bids shall be compared on the basis of number of units stated in the Bid Schedule as set forth in the Bidding Documents. Said unit prices shall be multiplied by the bid quantities for the total Bid price. Any Bid not conforming to this requirement may be rejected. Special attention to all Bidders is called to this provision, because if conditions make it necessary or prudent to revise the unit quantities, the unit prices will be fixed for such increased or decreased quantities. Compensation for such additive or subtractive changes in the quantities shall be limited to the unit prices in the Bid. Subsequent to the issuance of a notice to proceed, the Project Manager and the Successful Bidder shall have the discretion to re-negotiate any unit price(s) where the actual quantity varies by more than twenty-five percent (25%) from the estimate at the time of bid. 8 12-5948R Immokalee Rd Paved Shoulders Packet Page-816- 2/12/2013 11 .D. 11.2 Alternate Bid Pricing onsmo In the event that alternate pricing is requested, it is an expressed requirement of the bid invitation to provide pricing for all alternates as listed. The omission of a response or a no-bid or lack of a submitted price may be the basis for the rejection of the submitted bid response. All bids responses received without pricing for all alternates as listed will be considered technically non-responsive and will not be considered for award. Section 12. Award of Contract 12.1 Any prospective bidder who desires to protest any aspect(s) or provision(s) of the bid invitation (including the form of the bid documents or bid procedures) shall file their protest with the Purchasing Director prior to the time of the bid opening strictly in accordance with Owner's then current Purchasing Policy. 12.2 Statement of Award: The Award of Contract shall be issued to the lowest, responsive and qualified Bidder determined by the base bid, and any, or all, selected alternates, and the Owner's investigations of the Bidder. In determining the lowest, responsive and qualified bidder, the Owner shall consider the capability of the Bidder to perform the contract in a timely and responsible manner. When the contract is awarded by Owner, such award shall be evidenced by a written Notice of Award, signed by a Purchasing professional of the Owner's Purchasing Department or his or her designee and delivered to the intended awardee or mailed to awardee at the business address shown in the Bid. 12.3 Award recommendations will be posted outside the offices of the Purchasing Department generally on Wednesdays or Thursdays prior to the presentation to the Board of County Commissioners. Award of Contract will be made by the Board of County Commissioners in public session. Any actual or prospective bidder who desires to formally protest the recommended contract award must file a notice of intent to protest with the Purchasing Director within two (2) calendar days (excluding weekends and holidays) of the date that the recommended award is posted. Upon filing of said notice, the protesting party will have five (5) days to file a formal protest, said protest to strictly comply with Owner's then current Purchasing Policy. A copy of the Purchasing Policy is available at http://www.collieroov.net/Index.aspx?page=762. 12.4 For Bidders who may wish to receive copies of Bids after the Bid opening, The Owner reserves the right to recover all costs associated with the printing and distribution of such copies. 12.6 Certificate of Authority to Conduct Business in the State of Florida (Fl St 607.1501) In order to be considered for award, firms submitting a response to this solicitation shall be required to provide a certificate of authority from the Florida Department of State Divisions of Corporations in accordance with the requirements of Florida Statute 607.1501 (www.sunbiz.org/search.html). A copy of the document shall be submitted with the solicitation response and the document number shall be identified. Firms who do not provide the certificate of authority at the time of response shall be required to same within five (5) days upon notification of selection for award. If the firm cannot provide the document within the referenced timeframe, the County reserves the 9 12-5948R Immokalee Rd Paved Shoulders Packet Page-817- 2/12/2013 11.D. right to award to another firm. 12.7 Local Vendor Preference: The Collier County Board of County Commissioners has adopted a Local Preference "Right to Match" policy to enhance the opportunities of local businesses to receive awards of Collier County contracts. A "local business" is defined as a business that has a valid occupational license issued by either Collier or Lee County for a minimum of one (1) year prior to a Collier County bid or proposal submission that authorizes the business to provide the commodities or services to be purchased, and a physical business address located within the limits of Collier or Lee Counties from which the vendor operates or performs business. Post Office Boxes are not verifiable and shall not be used for the purpose of establishing said physical address. In addition to the foregoing, a vendor shall not be considered a "local business" unless it contributes to the economic development and well-being of either Collier or Lee County in a verifiable and measurable way. This may include, but not be limited to, the retention and expansion of employment opportunities, the support and increase to either Collier or Lee County's tax base, and residency of employees and principals of the business within Collier or Lee County. Vendors shall affirm in writing their compliance with the foregoing at the time of submitting their bid or proposal to be eligible for consideration as a "local business" under this section. When a qualified and responsive, non-local business submits the lowest price bid, and the bid submitted by one or more qualified and responsive local businesses is within ten percent (10%) of the price submitted by the non-local business, then the local business with the apparent lowest bid offer (i.e. the lowest local bidder) shall have the opportunity to submit, an offer to match the price(s) offered by the overall lowest, qualified and responsive bidder. In such instances, staff shall first verify if the lowest non-local bidder and the lowest local bidder are in fact qualified and responsive bidders. Next, the Purchasing Department shall determine if the lowest local bidder meets the requirements of Section 287.087 F.S. If the lowest local bidder meets the requirements of 287.087, F.S., the Purchasing Department shall invite the lowest local bidder to submit a matching offer to the Purchasing Department which shall be submitted within five (5) business days thereafter. If the lowest local bidder submits an offer that fully matches the lowest bid from the lowest non-local bidder tendered previously, then award shall be made to the local bidder. If the lowest local bidder declines or is unable to match the lowest non local bid price(s), then award will be made to the lowest overall qualified and responsive bidder. If the lowest local bidder does not meet the requirement of Section 287.087 F.S. and the lowest non-local bidder does, award will be made to the bidder that meets the requirements of the reference state law. Bidder must complete and submit with their bid response the Affidavit for Claiming Status as a Local Business which is included as part of this solicitation. Failure on the part of a Bidder to submit this Affidavit with their bid response will preclude said Bidder from being considered for local preference on this solicitation. A Bidder who misrepresents the Local Preference status of its firm in a bid submitted to the County will lose the privilege to claim Local Preference status for a period of up to one (1) year. 10 12-5948R Immokalee Rd Paved Shoulders Packet Page -818- 2/12/2013 11 .D. The County may, as it deems necessary, conduct discussions with responsible bidders determined to be in contention for being selected for award for the purpose of clarification to assure full understanding of, and responsiveness to solicitation requirements. Section 13. Sales Tax 13.1 The Successful Bidder acknowledges and agrees that Owner may utilize a sales tax savings program and the Successful Bidder agrees to fully comply, at no additional cost to Owner, with such sales tax savings program implemented by the Owner as set forth in the Agreement and in accordance with Owner's policies and procedures. Section 14. Exclusion of County Permits in Bid Prices 14.1 To ensure compliance with Section 218.80, F.S., otherwise known as "The Public Bid Disclosure Act", Collier County will pay for all Collier County permits and fees applicable to the Project, including license fees, permit fees, impact fees or inspection fees applicable to this Work through an internal budget transfer(s). Hence, bidders shall not include these permit/fee amounts in their bid offer. However, the Successful Bidder shall retain the responsibility to initiate and complete all necessary and appropriate actions to obtain the required permits other than payment for the items identified in this section. 14.2 The Successful Bidder shall be responsible for procuring and paying for all necessary permits not issued by Collier County pursuant to the prosecution of the work. Section 15. Use of Subcontractors 15.1 To ensure the Work contemplated by the Contract Documents is performed in a professional and timely manner, all Subcontractors performing any portion of the work on this Project shall be "qualified" as defined in Collier County Ordinance 87-25, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements and has the integrity and reliability to assure good faith performance. A Subcontractor's disqualification from bidding by the Owner, or other public contracting entity within the past twelve months shall be considered by the Owner when determining whether the Subcontractors are "qualified." 15.2 The Owner may consider the past performance and capability of a Subcontractor when evaluating the ability, capacity and skill of the Bidder and its ability to perform the Agreement within the time required. Owner reserves the right to disqualify a Bidder who includes Subcontractors in its bid offer which are not "qualified" or who do not meet the legal requirements applicable to and necessitated by this Agreement. 15.3 The Owner may reject all bids proposing the use of any subcontractors who have been disqualified from submitting bids to the Owner, disqualified or de-certified for bidding purposes by any public contracting entity, or who has exhibited an inability to perform through any other means. Amok 15.4 Notwithstanding anything in the Contract Documents to the contrary, the Bidder shall identify the subcontractor(s) it intends to use for the categories of work as set forth 11 12-5948R Immokalee Rd Paved Shoulders Packet Page-819- 2/12/2013 11.D. in the List of Subcontracts attached hereto, said list to be submitted with its bid. Bidders acknowledge and agree that the subcontractors identified on the list is not a complete list of the subcontractors to be used on the Project, but rather only the major subcontractors for each category of Work as established by Owner. Bidders further acknowledge that once there is an Award of Contract, the Successful Bidder shall identify, subject to Owner's review and approval, all the subcontractors it intends to use on the Project. Once approved by Owner, no subcontractor shall be removed- or replaced without Owner's prior written approval. Section 16. Prohibition of Gifts No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part Ill, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and/or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual and/or firm for cause. Section 17. Lobbying All firms are hereby placed on NOTICE that the Board of County Commissioners does not wish to be lobbied, either individually or collectively about a project for which a firm has submitted a response. Firms and their agents are not to contact members of the County Commission for such purposes as meeting or introduction, luncheons, dinners, etc. During the process, from solicitation closing to final Board approval, no firm or their agent shall contact any other employee of Collier County in reference to this solicitation, or the vendor's response, with the exception of the Purchasing Director or his designee(s). Failure to abide by this provision may serve as grounds for disqualification for award of this contract to the firm. Section 18. Public Entity Crimes By its submitting a Bid, Bidder acknowledges and agrees to and represents it is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity'; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." 12 12-5948R Immokalee Rd Paved Shoulders Packet Page -820- 2/12/2013 11 .D. Amook CONSTRUCTION BID BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge#030160) BID NO. 12-5948R Full Name of Bidder COMMUNITY ASPHALT CORP. Main Business Address 9725 NW 117th Avenue, Suite 110, Miami, FL 33178 Place of Business 14005 NW 186th Street, Hialeah, FL 33018 Telephone No. (239) 337-9486 Fax No. (239) 337-9488 State Contractor's License# CGC011475 State of Florida Certificate of Authority Document Number 688538 Federal Tax Identification Number 59-2023298 To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA (hereinafter called the Owner) The undersigned, as Bidder declares that the only person or parties interested in this Bid as principals are those named herein, that this Bid is submitted without collusion with any other person, firm or corporation; that it has carefully examined the location of the proposed Work, the proposed form of Agreement and all other Contract Documents and Bonds, and the Contract Drawings and Specifications. Bidder proposes, and agrees if this Bid is accepted, Bidder will execute the Agreement included in the Bidding Documents, to provide all necessary machinery, tools, apparatus and other means of construction, including utility and transportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the Contract, and to do all other things required of the Contractor by the Contract Documents, and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points, and in the case where further decimal points are inadvertently provided, rounding to two decimal points will be conducted by Purchasing staff. NOTE: If you choose to bid, please submit an ORIGINAL and ONE COPY of your bid pages. 13 12-5948R Immokalee Rd Paved Shoulders Packet Page -821- PM: Julio Ordonez ITB 12-5948R 2/12/2013 11 .D. PS: Brenda Brilhart Immokalee Raod Pave Shoulder Improvements ITEM No DESCRIPTION UNIT QUANTITY. UNIT PRICE , AMOUNT, ,J1-1 MOBILIZATION LS 1 $78,266.20 $ 78,266.20 102-1 MAINTENANCE OF TRAFFIC LS 1 $58,415.00 $ 58,415.00 102-3 COMMERCIAL MATERIAL FOR DRIVEWAY MAINTENANCE 100 $16.65 $ ___ 1,665.00.__ 104-10-2 SYNTHETIC BALES LF 10,000 $4.80 $ 48,000.00 104-13-1 STAKED SILT FENCE TYPE III LF 97,000 $0.45 $ 43,650.00 110-1-1 STANDARD CLEARING&GRUBBING LS 1 $84,155.00 $ 84,155.00 120-1 EXCAVATION CY 8,981 $3.55 $ 31,882.55 120-6 EMBANKMENT CY 4,491 $5.55 $ 24,925.05 160-4 TYPE B STABILIZATION SY 21,556 $3.35 $ 72,212.60 210-2 LIMEROCK, NEW MATERIAL FOR REWORKING EXIST. BASE CY 50 $16.60 $ 830.00 285-701 OPTIONAL BASE GROUP 1 (4"THICK) SY 58,889 $6.00 $ 353,334.00 285-709 OPTIONAL BASE GROUP 9(6"THICK) SY 2,018 $16.70 $ 33,700.60 286-1 TURNOUT CONSTRUCTION,ASPHALT SY 500 $64.55 $ 32,275.00 334-1-13 SUPERPAVE ASPH. CONC. TYPE SP(1.5"THICK,TRAFFIC C) TN 4,846 $86.15 $ 417,482.90 334-1-132 SUPERPAVE ASPH. CONC. TYPE SP(2"THICK,TRAFFIC C) TN 236 $118.05 $ 27,859.80 339-1 MISCELLANEOUS ASPHALT PAVEMENT TN 20 $201.45 $ 4,029.00 430-985-230 MITERED END SECTION(30",CD) EA 2 $3,285.00 $ 6,570.00 522-2 CONCRETE SIDEWALK,6"THICK(TURNOUTS) SY 125 $37.70 $ 4,712.50 530-1 RIPRAP(SAND-CEMENT) CY 280 $307.45 $ 86,086.00 536-1-1 GUARDRAIL(ROADWAY) LF 600 $12.70 $ 7,620.00 536-7 GUARDRAIL POST,SPECIAL EA 6 $190.85 $ 1,145.10 536-85-22 GUARDRAIL ANCHORAGE SYSTEM(FLARED) EA 8 $1,565.00 $ 12,520.00 '0-1-2 PERFORMANCE TURF(SOD) SY 215,556 $1.65 $ 355,667.40 ,0-20-11 SIGNS, SINGLE POST AS 30 $213.10 $ 6,393.00 700-46-1 EXISTING SIGN, REMOVE AS 20 $1.05 $ 21.00 700-46-2 EXISTING SIGN, RELOCATE AS 20 $71.05 $ 1,421.00 701-1 NV PAVEMENT MARKINGS-TRANSVERSE BARS(6"WIDE) NM 1.820 $4,770.00 $ 8,681.40 705-10-3 OBJECT MARKER TYPE 3 EA 10 $136.75 $ 1,367.50 706-3 PAVEMENT MARKERS, RETRO-REFLECTIVE EA 2,422 $3.35 $ 8,113.70 711-11-111 TRAFFIC STRIPE SOLID,THERMOPLASTIC-WHITE(6") NM 18.340 $3,655.00 $ 67,032.70 711-11-124 TRAFFIC STRIPE SOLID,THERMOPLASTIC-WHITE(18") LF 4,585 $4.00 $ 18,340.00 711-11-125 TRAFFIC STRIPE SOLID,THERMOPLASTIC-WHITE(24") LF 200 $5.85 $ 1,170.00 $ 1,899,544.00 999-102 SPEED&LAW ENFORCEMENT OFFICER MH 80 $60.00 $4,800.00 TOTAL $ 1,904,344.00 Packet Page-822- 2/12/2013 11 .D. MATERIAL MANUFACTURERS THIS FORM MUST BE COMPLETED OR BID SHALL BE DEEMED NON- RESPONSIVE All Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this Bid specifications. Exceptions (when equals are acceptable) may be requested by completing the Material Manufacturer Exception List below. If an exception for a manufacturer and/or material is proposed and listed below and is not approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in the specification. Acceptance of this form does not constitute acceptance of material proposed on this list. Complete and sign section A OR B. Section A(Acceptance of all manufactures and materials in Bid specifications) On behalf of my firm, I confirm that we will use all manufacturers and materials as specifically outlined 'n the Bid specifications. company: COMM PHALT CORP. Signature: �� Date: 12/18/12 MANUEtz,A LIAR / VICE PRESIDENT Section B (Exception requested to Bid specifications manufacturers and materials) EXCEPTION MATERIAL EXCEPTION MANUFACTURER 1. 2. 3. 4. 5. Please insert additional pages as necessary. Company: Signature: Date: 15 12-5948R Immokalee Rd Paved Shoulders Packet Page-823- 2/12/2013 11 .D. LIST OF MAJOR SUBCONTRACTORS THIS LIST MUST BE COMPLETED OR BID MAY BE DEEMED NON-RESPONSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories outlined in the requirements of the Bid specifications. The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the major categories listed herein are "qualified" (as defined in Ordinance 87-25 and Section 15 of Instructions to Bidders) and meet all legal requirements applicable to and necessitated by the Contract Documents, including, but not limited to proper licenses, certifications, registrations and insurance coverage. The Owner reserves the right to disqualify any Bidder who includes non-compliant or non-qualified Subcontractors in its bid offer. Further, the Owner may direct the Successful Bidder to remove/replace any Subcontractor, at no additional cost to Owner, which is found to be non-compliant with this requirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents, the Successful Bidder shall identify all Subcontractors it intends to use on the Project. The undersigned further agrees that all Subcontractors subsequently identified for any portion of work on this Project must be qualified as noted above. Major Category of Work Subcontractor and Address 1. Electrical 2. Mechanical 3. Plumbing 4. Site Work �o s �.A Gp.PaL �1X15S4%'��Z5 5. Identify other subcontractors that G tRv'C $ represent more than 10% of price or that affect the critical path of the schedule 6. Identify other c 5 4.4 subcontractors that represent more than 10% of price or that affect the critical path of the schedule 7. Identify other subcontractors that represent more than 10% of price or that affect the critical path 16 12-5948R Immokalee Rd Paved Shoulders Packet Page-824- 2/12/2013 11 .D. Aloft of the schedule 8. Identify other subcontractors that represent more than 10% of price or that affect the critical path of the schedule 9. Identify other subcontractors that represent more than 10% of price or that affect the critical path of the schedule 10. Identify other subcontractors that represent more than 10% of price or that affect the critical path of the schedule Company: COMMUNITY = ' LT CORP. Signature: Date: 12/18/12 MANUEL AGU '1 ICE PRESIDENT 17 12-5948R Immokalee Rd Paved Shoulders Packet Page-825- 2/12/2013 11 .D. STATEMENT OF EXPERIENCE OF BIDDER The Bidder is required to state below what work of similar magnitude completed within the last five years is a judge of its experience, skill and business standing and of its ability to conduct the work as completely and as rapidly as required under the terms of the Agreement. Project and Location Reference 1' PLEASE SEE ATTACHED - WORK EXPERIENCE 2. 3. 4. 5. 6. Company: COMMUNITY AS •T CORP. i Signature: Date: 12/18/12 MANUEL AGUI I E PRESIDENT 18 12-5948R Immokalee Rd Paved Shoulders Packet Page -826- 2/12/2013 11 .D. TRENCH SAFETY ACT Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act(90-96, Laws of Florida) effective October 1, 1990. The Bidder further identifies the cost to be summarized below: Trench Safety Units of Unit Unit Extended Measure Measure (Quantity) Cost Cost (Description) (LF,SY) 1. 2. 3. 4. 5. TOTAL $ ` ° Failure to complete the above may result in the Bid being declared non-responsive. Company: COMMUNITY ASP ,)CORP. Signature: / Date: 12/18/12 MANUEL AGUIA C PRESIDENT 19 Construction Services Agreement:Revised 08/15/2012 Packet Page-827- 2/12/2013 11 .D. r County Adn n atvve Seances Division ur:hasr: AFFIDAVIT FOR CLAIMING STATUS AS A LOCAL BUSINESS Solicitation#12-594BR Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to% Mile E of Bridge#030160) (CHECK APPROPRIATE BOXES BELOW) State of Florida(Select County if Vendor is described as a Local Business ❑ Collier County ❑ Lee County Vendor affirms that it is a local business as defined by the Purchasing Policy of the Collier County Board of County Commissioners and the Regulations Thereto. As defined in Section XI of the Collier County Purchasing Policy; A"local business" is defined as a business that has a valid occupational license issued by either Collier or Lee County for a minimum of one (1) year prior to a Collier County bid or proposal submission that authorizes the business to provide the commodities or services to be purchased, and a physical business address located within the limits of Collier or Lee Counties from which the vendor operates or performs business. Post Office Boxes are not verifiable and shall not be used for the purpose of establishing said physical address. In addition to the foregoing, a vendor shall not be considered a "local business"unless it contributes to the economic development and well-being of either Collier or Lee County in a verifiable and measurable way.This may include, but not be limited to, the retention and expansion of employment opportunities, the support and increase to either Collier or Lee County's tax base, and residency of employees and principals of the business within Collier or Lee County. Vendors shall affirm in writing their compliance with the foregoing at the time of submitting their bid or proposal to be eligible for consideration as a "local business" under this section. Vendor must complete the following information: Year Business Established in OCollier County or ❑ Lee County: 2011 Number of Employees(Including Owner(s)or Corporate Officers):601 Number of Employees Living in❑ Collier County or❑ Lee(Including Owner(s)or Corporate Officers): 18 If requested by the County,vendor will be required to provide documentation substantiating the information given in this affidavit. Failure to do so will result in vendor's submission being deemed not applicable. Vendor Name: COMMUNITY ASPHALT CORP. Date: 12/18/12 Collier or Lee County Addr:.s: 16560 Mass Court, Fort Myers, FL 33912 Signature: — 1 Title: Vice President MANUEL A" P • R /VICE PRESIDENT STATE OF FLORIDA: ! COL IER COUNTY II LEE COUNTY Sworn to and Subscribed Before Me,a Notary Public,for the above State and County,on this 18 Day of ber420 t•7 Andrea Tre�s 4 +"'.' ANDREA TRELLES Notary Public Public-State of Florida 8/4/16 EE 202902 • '• • My Comm.Expires Aug 4,2016 My Commission Expires: 8/4/16 Commissions EE 202902 ft.°I Bonded Through National Notary Assn. f (AFFIX OFFICIAL SEAL) 20 Construction Services Agreement:Revised 08/15/2012 Packet Page-828- 2/12/2013 11 .D. Colter County Altitst Adminstrabve Servicses pension zurchasna Immigration Law Affidavit Certification 12-5948R Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge#030160) This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with formal Invitations to Bid (ITB's)and Request for Proposals (RFP) submittals. Further, Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the vendor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Failure to include this Affidavit and acceptable evidence of enrollment in the E-Verifv program. may deem the Bidder's proposal as non-responsive. Collier County will not intentionally award County contracts to any vendor who knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 U.S.C. Section 1324 a(e)Section 274A(e) of the Immigration and Nationality Act("INA"). Collier County may consider the employment by any vendor of unauthorized aliens a violation of Section 274A (e) of the INA. Such Violation by the recipient of the Employment Provisions contained in Section 274A(e)of the INA shall be grounds for unilateral termination of the contract by Collier County. Vendor attests that they are fully compliant with all applicable immigration laws(specifically to the 1986 Immigration Act and subsequent Amendment(s))and agrees to comply with the provisions of the Memorandum of Understanding with E-Verify and to provide proof of enrollment in The Employment Eligibility Verification System(E-Verify),operated by the Department of Homeland Security in partnership with the Social Security Administration at the time of submission of the Vendor's/Bidder's proposal. Company Name COMMUNITY ASPHALT CORP. Print Name MANUEL AG AR Title VICE PRESIDENT Signature I Date 12/18/12 • State of FLORIDA County of LEE The foregoing instrument was signed and acknowledged before me this 18 day of December , 20 ,by Mhi&UELiii UIAR (print or type name)who has produced pe of identification and number)as identification. 1�— Notary Public Signature .�` ANDREA TRELLES 1 l'% Notary Public-State of Florida ANDREA TRELLES ? My Comm.Expires Aug 4.2016 ";F��o= Commission#EE 202902 Printed Name of Notary Public ,,, Bonded Through National Notary Assn. 4_,._-1.-.... EE 202902 / 8/4/16 Notary Commission Number/Expiration The signee of this Affidavit guarantees, as evidenced by the sworn affidavit required herein,the truth and accuracy of this affidavit to interrogatories hereinafter made. 21 Construction Services Agreement:Revised 08/15/2012 Packet Page-829- 2/12/2013 11 .D. cotter copy Actninistrab„e Services Division =ur hasim COLLIER COUNTY SOLICITATIONS SUBSTITUTE W—9 Request for Taxpayer Identification Number and Certification In accordance with the Internal Revenue Service regulations, Collier County is required to collect the following information for tax reporting purposes from individuals and companies who do business with the County(including social security numbers if used by the individual or company for tax reporting purposes). Florida Statute 119.071(5) require that the county notify you in writing of the reason for collecting this information, which will be used for no other purpose than herein stated. Please complete all information that applies to your business and return with your quote or proposal. 1. General Information(provide all information) Taxpayer Name COMMUNITY ASPHALT CORP. (as shown on income tax retumL Business Name COMMUNITY ASPHALT CORP. (if Address en1 bU Mass Court City Fort Myers State Florida Zip 33912 Telephone 2:19-M7-9486 FAX 239-337-9488 Email MGRAF @CACORP.NET Order Information Remit/Payment Information Address Address City State Zip City State Zip FAX FAX Email Email 2. Company Status(check only one) _Individual/Sole Proprietor FrICorporation _.Partnership Tax Exempt(Federal income tax-exempt entity _Limited Liability Company under Internal Revenue Service guidelines IRC 501 (c)3) C Enter the tax classification (D=Disregarded Entity, C=Corporation,P=Partnership) 3. Taxpayer Identification Number(for tax reporting purposes only) Federal Tax Identification Number(TIN) 59-2023298 (Vendors who do not have a TIN,will be required to provide a social security number prior to an award of the contract.) 4. Sign and Date Form Certification:Under penalties of perjury,I certify that the information shown on this form is correct to my knowledge. Signature MANU .i IIAR Date 12/18/12 Title • ►'. ► Phone Number 305-829-07n0 22 Construction Services Agreement:Revised 08/15/2012 Packet Page-830- 2/12/2013 11 .D. Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement form attached to the Bidding Documents within ten (10) calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents. The bid security attached is to become the property of the Owner in the event the Agreement, Insurance Certificates and Bonds are not executed and delivered to Owner within the time above set forth, as liquidated damages, for the delay and additional expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period. In the event of such failure, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it fails to execute and deliver the Agreement, Insurance Certificates, and Bonds as required hereunder. The Successful Bidder hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely manner. Upon receipt of the Notice of Award, the undersigned proposes to commence work at the site within five (5) calendar days from the commencement date stipulated in the written Notice to Proceed unless the Project Manager, in writing, subsequently notifies the Contractor of a modified (later) commencement date. The undersigned further agrees to substantially complete all work covered by this Bid within one hundred and eighty (180) consecutive calendar days, computed by excluding the commencement date and including the last day of such period, and to be fully completed to the point of final acceptance by the Owner within thirty (30) consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. Respectfully Submitted: State of FLORIDA County of LEE MANUEL AGUIAR , being first duly sworn on oath deposes and says that the Bidder on the above Bid is organized as indicated and that all statements herein made are made on behalf of such Bidder and that this deponent is authorized to make them. MANUEL AGUIAR , also deposes and says that it has examined and carefully prepared its Bid from the Bidding Documents, including the Contract Drawings and Specifications and has checked the same in detail before submitting this Bid; that the statements contained herein are true and correct. 23 12-5948R Immokalee Rd Paved Shoulders Packet Page -831- 2/12/2013 11 .D. (a) Corporation The Bidder is a corporation organized and existing under the laws of the State of FLORIDA which operates under the legal name of , and the full names of its officers are as follows: President John Morris Secretary Agustin Arellano Jr. Treasurer Agustin Arellano Jr. Manager Manuel Aguiar The Manager is authorized to sign construction bids and contracts for the company by action of its Board of Directors taken , a certified copy of which is hereto attached (strike out this last sentence if not applicable). (b)Co-Partnership The Bidder is a co-partnership consisting of individual partners whose full names are as follows: The co-partnership does business under the legal name of: (c) Individual The Bidder is an individual whose full name is , and if operating under a trade name, said trade name is 24 12-5948R Immokalee Rd Paved Shoulders Packet Page-832- 2/12/2013 11 .D. Complete for information contained in (a) Corporation, (b) Co-Partnership or (c) Individual from previous page. DATED 12/18/12 COMMUNITY ASPHALT CORP. / legal entity Y i ii.a . //i BY: MANUEL AGUIAR Nikt..--... Ati — .. . /40 .., ,,,,_41 -, Name of Bidd r(Typed) Witness Signature . VICE PRESIDEtNT Title STATE OF FLORIDA COUNTY OF LEE The foregoing instrument was acknowledged before me this 18 day of DECEMBER , 2012 , by MANUEL AGUIAR , as VICE PRESIDENT of a corporation, on behalf of the corporation. }je/she is personally known to me or has produced - identification and did (did not)take an oath. ^ _ • My Commis ' N•"""% ANDREA TRELLES (Signature of Notary) t-- Notary Public-State of Florida __• -•: My Comm.Expires Aug 4,kik ANDREA TRELLES $, = Commission 41 EE 2029DY'' Printed) *•'•� Bonded Through National Notary Assn (Legibly ) (AFFIX OFFICIAL SEAL) Notary Public, State of FLORIDA Commission No.: EE 202902 25 12-5948R Immokalee Rd Paved Shoulders Packet Page-833- ` 2/12/2013 11 .D. BID BOND KNOW ALL MEN BY THESE PRESENTS, that we Community Asphalt Corp. (herein after called the Principal) and Travelers Casualty and Surety Company of America , (herein called the Surety), a corporation chartered and existing under the laws of the State of CT with its principal offices in the city of Hartford,CT and authorized to do business in the State of FL are held and firmly bound unto the Collier County Government,FL (hereinafter called the Owner), in the full and just sum of Five Percent of the Total Amount Bid dollars ($5%of Amount Bid ) good and lawful money of the United States of America, to be paid upon demand of the Owner, to which payment well and truly to be made, the Principal and the Surety bind themselves, their heirs, and executors, administrators, and assigns, jointly and severally and firmly by these presents. Whereas, the Principal is about to submit, or has submitted to the Owner, a Bid for furnishing all labor, materials, equipment and incidentals necessary to furnish, install, and fully complete the Work on the Project known as 12-5948R Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 'A Mile E of Bridge #030160) NOW, THEREFORE, if the Owner shall accept the Bid of the PRINCIPAL and the PRINCIPAL shall enter into the required Agreement with the Owner and within ten days after the date of a written Notice of Award in accordance with the terms of such Bid, and give such bond or bonds in an amount of 100% the total Contract Amount as specified in the Bidding Documents or Contract Documents with good and sufficient surety for the faithful performance of the Agreement and for the prompt payment of labor, materials and supplies furnished in the prosecution thereof or, in the event of the failure of the PRINCIPAL to enter into such Agreement or to give such bond or bonds, and deliver to Owner the required certificates of insurance, if the PRINCIPAL shall pay to the OBLIGEE the fixed sum of $5%of Amount Bid noted above as liquidated damages, and not as a penalty, as provided in the Bidding Documents, then this obligation shall be null and void, otherwise to remain in full force and effect. IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly signed and sealed this 7th ,of December 2012 . Community As halt Corp. Principal BY ) MANUEL AGUIAR, VICE PRESIDENT .(Seal) Travelers Cas an Surety Company of America Sttre'ty Je "i i t. - t e 1_.41e Seal 4 Countersigned ` , ._U pi') 117 :7)-(..e,t`.-4 a. ?/ (0 t Local Resident Produ ing Agent for Joseph M.Pietrangelo,Attorney-In-Fact&FL Resident Agent Aon Risk Services:1001 Brickell Bay Drive,Suite 1100,Miami,FL 33131 26 12-5948R lmmokalee Rd Paved Shoulders Packet Page-834- WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER 2/12/2013 11 .D. ,wk POWER OF ATTORNEY TRAVELERSJ Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company Attorney-In Fact No. 224611 Certificate No. 005251535 KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company,St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa,and that Fidelity and Guaranty Insurance Underwriters,Inc.,is a corporation duly organized under the laws of the State of Wisconsin(herein collectively called the"Companies"),and that the Companies do hereby make,constitute and appoint Joseph M. Pietrangelo,and Claudette Alexander Hunt of the City of Miami ,State of Florida ,their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above,to sign,execute,seal and acknowledge any and all bonds,recognizances,conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF,the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed,this 31st day of October 2012 Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company ; Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company C 074. �,, 4,/' ,,,,..�F!1L0.'0J®�E^'yam^y1* 40,E hS`9's J+p,'■NSUgg4. 'J,tY AMOeG �.."4". l O C .SEAL `o/ "ASE LLia ;, ; 4 1951 E>!^ �. �; ° o 40 H ! 0 , �'',,.,e,ec e° lo%f. �At1 `:s.. .•.gas `4. ,At �' AINd�'. State of Connecticut By: Al City of Hartford ss. Robert L.Raney, enior Vice President On this the 31st day of October 2012 before me personally appeared Robert L.Raney,who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters,Inc.,St.Paul Fire and Marine Insurance Company,St.Paul Guardian Insurance Company.St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company,and that he,as such,being authorized so to do,executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. i+G•Ter In Witness Whereof,I hereunto set my hand and official seal. • W w" `' My Commission expires the 30th day of June,2016. O*USIA ,R Marie C.Tetreault,Notary Public 58440-8-12 Printed in U.S.A. WARNING:THIS POWER Packet Page-835-WITHOUT THE RED BORDER 2/12/2013 11 .D. THIS SHEET MUST BE SIGNED BY VENDOR BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA Purchasing Department BIDDERS CHECK LIST IMPORTANT: Please read carefully, sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: 1. The Bid has been signed. 2. The Bid prices offered have been reviewed. 3. The price extensions and totals have been checked. 4. Any required drawings, descriptive literature, etc. have been included. 5. Any delivery information required is included. 6. Local Vendor Preference Affidavit completed. 7. Immigration Affidavit completed and the company's E-Verify profile page or memorandum of understanding 8. Certificate of Authority to Conduct Business in State of Florida and the County's Substitute W9 9. If required, the amount of Bid bond has been checked, and the Bid bond or cashier's check has been included. 10.Any addenda have been signed and included. 11.The mailing envelope has been addressed to: Purchasing Director Collier County Government Purchasing Department 3327 Tamiami Trail E Naples FL 34112 12.The mailing envelope must be sealed and marked with: t=>Bid Number; Project Name; Opening Date. 13.The Bid will be mailed or delivered in time to be received no later than the specified opening date and time, otherwise Bid cannot be considered. ALL COURIER-DELIVERED BIDS MUST HAVE THE BID NUMBER AND PROJECT NAME ON THE OUTSIDE OF THE COURIER PACKET COMMUNITY A PHALT CORP. Bidder Name Signature &Title KlpitrE AGUIARNICE PRESIDENT Date: 12/18/12 27 12-5948R Immokalee Rd Paved Shoulders Packet Page-836- 2/12/2013 11 .D. Co . ,,. County Email: BrendaBrilhart@colliergov.net Telephone: (239)252-8446 Acirrinistreve Seivi Division FAX: (239)252-6697 rcha*g ADDENDUM #1 Memorandum Date: December 11, 2012 From: Brenda Brilhart, Procurement Strategist To: Interested Bidders Subject: Addendum # 1 — ITB 12-5948R- Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160) The following clarifications are issued as an addendum identifying the following changes for the referenced solicitation: ADD: • Revised Bid Schedule and Plan Set moo* • Revised plan sheets showing the Audible & Vibratory Pavement Marking. QUESTIONS/ANSWERS: • Q: White Markings—A: Audible & Vibratory Pavement Markings (Bid Item) is being increased to include the edge lines for curves 2 and 3. The original bid had the double yellow replacement with AN striping only. The quantity was double and the bid item changed from 7-1-11-211 to 701-1). • Q: Guardrail —A: The guardrail installation at the existing 30" RCP will not be installed during construction, the construction of the mitered end sections will be done instead. This change will be reflected in the SFWMD permit certification at the end of the project. • Q: Pay item Optional Base 1 — is this FDOT spec? A: Yes • Q: Any night or weekend work? A: No, and lane closures will be restricted during project. • Q: Will the road be staked with Station Boards? A: No, measure in field. If you require additional information please post a question on the Online Bidding site or contact me using the above contact information. c: Julio Ordonez, Project Manager Enc: Revised Bid Schedule v,�/�f-`itt Plan Set 1 Packet Page-837- 2/12/2013 11 .D. ,. = OH COMMUNITY ASPHALT CORP. SHEET NO. 3'w:41:4- Comm un From 2007 to 2011 (1 1 `' Asphalt Contracts Completed Within The Past Five Years C7 - t Projec4 o.ees Fiscal escrip ion —Contract-Owner/Prime— x « t Job No. Yr. . 4595 5,6,7 2007 FDOT#410612-1-52-01 FDOT $ 396,843.00 Mechanical Sweeping SR-A1A I MDX#50008 Miami Dade Expressway 2 ,,,, 4' 15 6,7,9 2007 $ �,ttzl 6�-,.,79 I I E Construction Management Services Authorities __-_ 0L35 6,7,8,9 2007 Miami International Airport; HJ Apron Gilbert Southern $ 2,312 199� Q: 5000 5,6,7,9 2007 FDOT#229499-1-52-01 FDOT 21,621,023.05 $ 20;435,489.00 SR-80 (Southern Blvd) 5010 5,6,7,9 2008 FDOT#229587-2-52-01 FDOT SR-809(Military Trail) 4,",,4;, r FDOT#229797-1-52-01 5015 5,6,7,9 2008 SR 80(Southern Blvd) Archer Western $ 5,900,000.00 Miami Dade Expressway 205 5,6,7,8 2007 Design Build SR-836 Extension $ 177,565,761.00 Authorities 5263 6,7,8 2008 East Lake Village Rio-Bak Corp $ 862,765.00 Grand Dr/Hillmoor Drive 6290 5,7,9 2007 FDOT#228223-1-52-01 FDOT $ 8,421,634.16 SR-5(US 1) i 5310 5,6,7,9 2007 Miami Intermodal Center-GMP 2 Turner Construction $ 699,0r 1.00 5340 5.6,7,9 2007 FDOT#229818 1 52 01 SR-15 -FDOT S 16,791,?;8,13 5370` 5,6,7,8 2008 Miami International Airport Gilbert Southern $ 3,466,237.00 MIC Connector 5375 5,6 2010 FDOT#408520-1-72-03 FDOT $ 1.299,260.00 Asphalt Maintenance in Various Locations 5440��` 5,6,7,9 2007 FDOT#229833-2-52-01 FDOT S 612,655.62 Push Button FDOT#412754-1-52-01/2-52-01 5450 5,6,7,9 2007 FDOT $ 5,074,223.00 SR-909(W. Dude Hwy) FDOT No. 403619-1-52-01 5490 5,6,7,9 2007 FDOT $. 277 7,6 5.$3 SR-710 Rev�sc 4, 3t1 (se Packet Page -838- 2/12/2013 11 .D. OHL COMMUNITY ASPHALT CORP. 'SHEET NO. .. 7 (2) Community From 2007 to 2011 Asphalt Contracts Completed Within The Past Five Years al-4T- -FDOT#249835-2-5241 1 5,6,7, 2007 FDOT a a SR-5(US-1) 1 FDOT#231735-1-52-01 ` . 55(i `. 5,6,7,9 2008 FDOT#411279-1-52-01 FDOT $ 10 2s� �� ,' SR-9(1-75) 5,7,9 2007 Intersection Improvements Indrio Road St.Lucie County $ 816.853.00 5515 5,6,7,10 2008 FDOT#406092-2-52-01 Condotte America, Inc. $ 4,923.333.00 Atlantic Avenue 2.351;026.69 1 5520 5,6,7,9 2007 Big Pine Key X Monroe County S S Lawrence Rd.from Boyton Bch. Blvd.to 5521 7,8 2008 Bergeron Land Dev S 593,221.63 Gateway Blvd. 5540 5,6,7,9 2007 FDOT#250184-9-52-01 FDOT $ 832,213.99 Push-button,Traffic Operations 1 ■ I I 5549 5,6,7,9 2007 Millstone Landing Guettler&Sons $ 551,456.58 I I FDOT#406147-1-52-01 FDOT# 5555 5,6,7,9 2008 406119-4-52-01 Sawgrass FDOT S 57,556,362.00 Expressway Design Build Indian River County 5556 5,6,8 2008 Gulfstream Contractors Inc. $ 129,394.00 Administrative Complex 5558 5,6 2008 Oaks at Hobe Sound Palm Beach Grading $ 340,474.77 US-1 and Seabranch Blvd. 5560 6,7,8,9 2007 FDOT#228623-1-52-01:50th Avenue FDOT S 13,210,000.00 5564 7,8 2009 SR-5(US 1) Hubbard Construction S 4,636,767.62 Rio Mar Drive to Midway Road 5580 6,7 2008 FDOT#192910-1-72-06 FDOT $ 760,470.00 Mechanical Sweeping 559 6,7,9 2007 FDOT#192769 1-72-03 FDOT 5 472.945.00 Turnpike, Mechanical Sweeping 5594 5,6,7,9 2007 Roth Farms Warehouse Eden Construction $ 121,362.07 FDOT#406098-1-52-01 5615 5,6,7,9 2007 FDOT 2.255,396`03 SW 8th Street Exit Ramp Revised 4/23/12(se) Packet Page -839- 2/12/2013 11 .D. 4 HL COMMUNITY ASPHALT CORP. SHEET NO. 7 (3) ?° Community From 2007 to 2011 Asphalt Contracts Completed Within The Past Five Years 5621 5,6,7,9 2007 John I Leonard High School B&B Underground, Inc. . 63 ,3 . 5 ,tom ,: '1' FDOT#411435-1-52-01;T4099 ',- !Ilft 7'': '` 51325 5,6,7,9 2009 FDOT#231802-1-52-01 FDOT $ 8,056,498.00 SR-714 on SR-9 From A Pt West of SR-9 toAPtWestofSR-91 FDOT#414761-1-52-01;T6090 5630 5,6,7,9 2007 Kendall Drive, From SR-821 (North FDOT $ � 1.896518,43 I Ramp)to SW 102nd Avenue _ [5635 5,6,7,9 2007 FDOT#231726 1 52 O1 FDOT $ 4,956,050.74 SR-862/1-595 638 7,8 2008 Blue Water Bay W. Jackson & Sons c 137,765.00 FDOT#228615-1-52-01 ,I SR-5(US 1)Wabasso to Sebatian 1' 93.72 51340 . 7&8 2008 From a pt N of CR 510 to A Pt S of CR 512 r ' FDOT#411533-3-52-01/6-52-01 5645 7&8 2008 Milling and Resurfacing Travel Lanes FDOT 5 10,156,.3 FDOT $ 16,124,611,07 Shoulders and Roadway Safety _--1 51347 5,7,9 2007 Heron Bay Commercial All Rite Paving Contractors, Inc. $ 436,570.25 51350 5,6,7 2007 FDOT#229858-2-52-01 FDOT 4,100,350.46 SR-AIA(Ocean Boulevard) 51356 7,8 2009 South County Courthouse Mora Engineering $ 109,305.00 5665 5,7,9 2007 Crosstown Parkway, Segment 3 Johnson Brothers, Inc. $ 1,290.239.00 City of Port St. Lucie 5666 5,7,9 2007 F 414764-1-52-01 Condotte America, Inc. `$ 560,530.64 SR-826 826(NW 154th Street) 670 6,7,9 2007 5675 5,6,7,9 2007 FDOT#417159-1-52-01/1-56-01 FDOT $ 2,630,126.21 SR-AIA(Ocean Boulevard) FDOT#250172-2-52-01 FDOT p$ 1,188,200.50 Landscaping for SR-7 MDX#30011.060, No. ITB-06-05 5 @i&0 5,6,7,9 2007 Miami Dade Expressway Authorities $ 1,508,918.74 SR 878 Publix at Gateway Boulevard and 1 5682 6,9 2007 T.M. Russell $ 235,169.90 Conrgess Avenue .e, Revised 4/23/12(se) Packet Page -840- 2/12/2013 11 .D. A SHEET NO. t O H L COMMUNITY ASPHALT CORP. 7 (4) Community From 2007 to 2011 Asphalt Contracts Completed Within The Past Five Years Opa Locka Airport - 5683 5,7,9 2007 Master Excavators ; "� (Turnberry Airport) � " ^ FDOT#411322-1-52-01 w ; r 5685 6,8 2009 FDOT#412201-1-52-01 I- FDOT $ i 'A®"99 ;„, 75 Slip Ramp Milling and Resurfacing FDO#411436-1-52-01; E4133 5690 5,7,9 2007 SR-15/US-441 From PBC line to South of FDOT $ 1,149,349.141 SR-76 I 5692 5,7,9 2007 Sugar Mills Annual 2006 Rio-Bak Corporation S 427,135.10 i i 5695 5,7,9 2007 FDOT#227954-1-52-01 FDOT $ 2,907,310.23 s SR-844 j FDOT#249356-1-52-01 i 1 570O: . 5,8 2008 Design Build FDOT S 43,131,397.591 °", Reconstruction of SR-5 US. I 5707 6,7,8 2008 Sand Trail Palm Beach Grading S 712.053.00 j 1 I 5713 6,7,8 2008 Highland's Reserve Palm Beach Grading o.:. 270966.00 r - FDOT#415905-1-52-01 5720 6,7,8,9 2010 406104-1-52-01 Condotte America, Inc. $ 6,783,134.30 Okeechobee Mainlane Toll Plaza 5723 5,6,7,9 2007 St. Michael's High School T.M. Russell $ 247,272.95 I 5728 5,6,7,9 2007 Royal Concrete Concepts Eden Construction S 913,474,20 5734 '' 6,7,8 2008 Vizcaya Falls Palm Beach Grading S 152,447.00 5735 5,6,7,9 2008 PBC#2002103 Palm Beach County S 4,127,967.89 Ockeechobee Blvd 5739 5,6,7 2008 Palm Beach International Airport Mora Eng.Contractors, Inc. $ 130836.85 PBIA Garage#2 5744 5,6,7,9 2007 Bridgewater I Forest Hill Construction Inc. $ 139,463.91 95 Interchange&Indiantown Road 5750 5,6,7,9 2007 Waste Water Treatment Plan Arrow Asphalt $':. 130,574.70 5756 5,6,7,9 2007 Sunrise Key Conquest Engineering Revs;d 4/23/11 5.32 Packet Page-841- 2/12/2013 11 .D. ..1 ^ 0 H L COMMUNITY ASPHALT CORP, SHEET NO. ~rte=-? "A Community From 2007 to 2011 ttt;a _'_ Asphalt Contracts Completed Within The Past Five Years kx ice; '—---- 5760 5,6,7,9 2007 Sam's Club — Master Excavators $ 600,$1 �2; FDOT#405641-1-52-01 92 c;60 00 . 5761 6,8,9 2007 SR 5/US 1 Horizon Contractors $ ' - American Engineering&. �, 5769 6,8,9 2007 Walmart Superstore $ 1,009,,'1z..0: Development — V � 5770 6,7 2007 Rybovich Spencer Marina Ryan Sales and Service 914,07 2.00 Christopher Columbus High School 5774 5,7 2008 p 9 Stobs Brothers Contruction ; 310.C100.CC 3000 SW 87th Ave. FDOT#403617-1-52-01 5;'75 6,7,8 2008 SR25(US 27)from a pt S of 18th to a pt FDOT S +:9 ..53.83; of 37th Project#29-04-11-03 5777= 5,6,7,9 2008 City of Sunrise $ 2,933,653.00' Sunrise Lakes Blvd Creekside I 5778 7&8 2008 West of Turnpike on SR 70, St. Lucie Palm Beach Grading -,$ 138,041.50 County I 5 779 5,6,7,9 2007 Bella Terra North& South H & D Construction $ 156,'81.95 i 5'780 6,7 2008 FDOT#407630-2-52-01 FDOT $ 1,863,534.00 SR-826(Sunny Isles Blvd) 5789 7,8 2007 Provence Bay Sonic Engineering, Inc. S 106,170.00 .fir FDOT No.420289-4-52-01 5790 7,8 2008 Ramp Toll Plaza Conversion FDOT $ 914,822.95 Sawgrass Expressway 5795 6,7,8 2007 FDOT#418233-1-52-01 FDOT $ 3,397,795.00 SR-80 FDOT#420289-6-52-01 r--- 5800 5,6,7 2009 Design Build- Deerfield Mainline Toll FDOT S 44,744,748.55 Plaza Modifications Sawgrass 05 6,7,8 2007 FDOT#413802-1-52-01 _.....5_13. FDOT 1,644,173.00 SR-76 5807 5,6,7,9 2007 Martigale Estates Offsite Improvements Ryan Sales and Service $ 571.639.60 1 FDOT No. 415397-1-52-01 5810 5,6,7 2008 SR-93 (1-75)"Alligator Alley'from Collier FDOT S 14,458.803.01 L Co. Line to a pt. E of Snake Road 1 Revised 4/23/12(se) Packet Page -842- 2/12/2013 11 .D. SHEET NO. .' , O H L COMMUNITY ASPHALT CORP. 7 E i Community From 2007 to 2011 ??:..;,,; Asphalt Contracts Completed Within The Past Five Years a � ? • ■ - 'S.. -014-56-01— t:3 5815 6,7,8 2008 SR-15/80 from a pt S. of MLK Blvd.to a FDOT $" "'4 r' p t point S of Canal St t FDOT#228189-1-52-01 5;204 6,7,8 2008 SR-7(US 441)from apt S.of SR-816 to FDOT S 6,531,995.22" A Pt S of SR-870 5821– 5,7,9 2007 Quail Creek H &D Construction S 183 071.00 9 5822 , 5,7,9 2007 Ashley Lakes H &D Construction S 304.604.00 5825 5,6,7,9 2007 Palm West Business Park B&B Underground, Inc. $ 182,170.40 5827 6,7,9 2007 Campbell Facility Rio-Bak Corporation $ 130,862.20 I FDOT#405641-3-52-01 5830 7&8 2008 SR-5(Biscayne Blvd)from a pt S of NE FDOT $ 8,171,818 83 78th Street to NE 87th Street 5834 6,7,9 2007 Kithcing Creek Optimum Services, Inc. $ 103,44 .00 5836 6,7,9 2007 Dania Outside Storage Arrow Asphalt $ 103230.00 5840 6,7,9 2008 Catalina Atlanctic Southern Paving $ 209,335.00 5841 6,7,9 2007 Jenkins Road K-8 School Sheltra &Son Construction, Co. $ 306,888.00 American Engineering& S 562,307,00 5845 6,7,9 2008 Boca Town Center Development 5850 6,7,9 2009 MDX#ITB 07 03 Condotte America, Inc. S 1,014,002.10 SR-874 Ramp FDOT#229833-3-52-02 5855 5,6 2008 Pushbutton FDOT 500,009.76 41/41, Roadway Construction , '. 1-95 Aux Lanes SR. 5860 7&8 2008 9(1-95)from NW 127th St.to Opalocka Kiewit Southern Group $ 207,243.90 Blvd 5861 6,7,9 2007 Sugar Cane Warehouse#4 Rio-Bak Corporation $ 164,723.80 5865 6,7,9 2008 Port Of Miami; South Cargo Wharf Shoreline Foundation 344,768.00 Rehabilitaiton 5866 6,7,9 2007 South 26th Street Improvements Ric-Man International, Inc. 136.64325 Revered 4/23,12(se) ? Packet Page -843- 2/12/2013 11 .D. F .,.:,,, OH COMMUNITY ASPHALT CORP. SET NO. t: Community From 2007 to 2011 :_ Asphalt Contracts Completed Within The Past Five Years .fig; �: —5871 5,6,7 2009 Palm Beach Gardens High School B &B Underground, Inca 5875 6,7,8 2010 FDOT#227708-1-52-01 FDOT $ 17.6'C 3 50; C R-818 880 6,7,8 2008 FDOT#403577-1-52-01 FDOT $ 3,+ 1 5 y � ;u 2 SR-814 FDOT#413804-1-52-01 5885 6,7,8 2008 FDOT S 9,795,' 59.00 SR-15 ;889 7,8 2009 Croissant Park Basin A and B Conquest Engineering 246,300.75 FDOT#415367-1-52-01 SR 5390 8,9 2009 736 (Davie Blvd.) FDOT $ 3,437,441.061 from SW 38th Ave.to SW 25th Ave. 5,891 7&8 2008 37th Street Improvements CPS Contracting 8 200 8,95 37th from 58th to 66th FDOT#409409-1-52-01 5895 5,6,7 2009 SR-60 from Vero Beach Blvd.to Mocking FDOT x:531,126.89 Bird Drive. FDOT#411432-1-52-01 SR A1A 5900, 7, 8,9 2009 FDOT $ 7;347,333.fi5 From South of Sheridan Street to Cambridge Street 5902 5.6,8 2008 Paloma Palm Beach Grading 165,333.00 5904 5,6,8 2007 Kendall Pointe Budget Construction 8 102,095.00 5905 6,7,8,9 2010 Project#20060439 Miami Dade County 8 7,288.168.36 NE 2nd Ave FDOT#422816-1-52-01 5910 5,8 2008 FDOT#422817-1-52-01 FDOT S 12,778,172.96 Design Build Toll Plaza Homestead to Bird Road 5911 5,6,8 2007 Tuscany H &D Construction 8 182,131.00 5913 5,6,7 2008 Riverbend Corporate Park All-Rite Paving Contractors, Inc. 8 155,728.70 2255 West Broward Blvd. h-5-914 5,6,8 2007 Angler's Reef Atlantic Civil, Inc. Rev sd 4/23,11427( 72•00 Packet Page-844- iii, 2/12/2013 11 .D. >.: OH L COMMUNITY ASPHALT CORP. 7(jET NO. ...64A'.5 Community From 2007 to 2011 �... ' Asphalt Contracts Completed Within The Past Five Years 1 5916 5,6,7,9 2007 Capistara P.U.D. Belvedere Construction $' 2 ,g2 5917 5,6,7,9 2007 The Ranches SPS Contracting, Inc. $ 118,728.00' SR 60 1 . I 5918 5,6,8 2008 Cross Creek Lake Henry Fischer 4 109,378.00 1 5920 5,6,8 2007 Sam's Club American Engineering& $ 65:,.07 00 Development I . i Crestwood Boulevard and 9 e, Inc. S 121,121.10 Rosso Paving &Draina 5922 5,6,7,9 2007 9 Okeechobee Road i I I Holmberg Road 5929 . 5,6,7,9 2007 Arrow Asphalt& Engineering, Inc. $ 135,725.35 NW 61st Avenue to SR-7 I 5930 5,6,8 2008 Yamato Road Rosso Paving $ 139,2c 0.00 I i 5931 6,7,9 2007 Outdoor Resorts W.Jackson & Sons $ 163,744.51 5935 5,6,7 2009 Big Coppitt Waste Collection Systems Charley Toppinos& Sons $ 1,025,937.501 5938 7,9 2007 Eisenhower Elementary B& B Underground, Inc. $ 136,589.80 5940 6,7,8 2008 FDOT#416408-1-52-01 FDOT 5 2,400,178.00 SR-520 5942 5,6,8 2008 Miramar Business Center All-Rite Paving $ 131,427.00 Parcel C &D 5948 5,6,8 2007 Becker Road Felix Associates $ 356.648.00 5949 5,6,8 2007 Westmoreland Blvd Felix Associates $ 319,625.00 5950, 5,6,7,9 2008 MDX#ITB-07-07 Miami Dade Expressway $ 1,048,208 00 Systemwide Road Improvements Authorities i 5954 , 6,7,9 2008 Portofino Landings W. Jackson &Sons $ 259,130.00 Rev sed,4/23/12(sel` Packet Page -845- 2/12/2013 11 .D. OHL L COMMUNITY ASPHALT CORP. SHEET NO. "*� 7 9 ,.- Community From 2007 to 2011 t } Asphalt Contracts Completed Within The Past Five Years f -,;,� y<- — �' FIOT-#-da-X128- 52-01 � ,,� e�z 5255 6,7,8 2010 Pompano Beach Service Plaza The Tower Group $ ° 22 �l96.09 X960 7,8 2010 FDOT#411476-1-52-01 Freedom Pipeline $ 296,882. 32 Sebastian River Bridge PA 1`.�a9 5,6,8 2007 Area E Basin SE, Ph II Conquest Engineering $ 121,194.00 Al 59 a 5,6,8 2007 East Lake Village Rio-Bak Corporation $ 186,039.00 No.2008054 5965 5&7 2008 Annual Asphalt Milling and Resurfacing Palm Beach County S 4,290,322.51 Contract L ;967 6,7,8 2008 Peacock Blvd SAD Improvements Optimum Services, Inc. $ 302,761.44 I :;968 5,6,7,9 2007 Bayshore Repairs Felix Assocaites, LLC $ 316.822.74 I Key Deer Blvd 5970 7&8 2008 Monroe County $ 1,346,197.60 Improvements to Big Pine Key Duda 2007 F. 238 ,706.95 5972 5,6,7,9 2007 Duda Farms $ 2u 8,7C} CR-880 & Duda Road 5973 7,8 2008 Crostow Parkway Segment 2-Rdwy Felix Associates, LLC $ 1,891,1 51.09 5974 5,6,8 2008 Miami Shores 812 Watermain Budget Construction $ 377,475.00 2.9977 7,8 2008 Miramar Center Business Bldg C All-Rite Paving $ 208,562.00 5980 5,6,8 2009 Rosser Blvd W. Jackson &Sons $ 514 652.07 5984 5,7,9 2007 Sugar Mill Annual 2007 Rio-Bak Corporation $ 100,500.00 5985 6,7,8,9 2009 FDOT#414623-1-52-01 FDOT $ 2,858,106.52 SR-5 (Biscayne Blvd) FDOT#413837-1-52-01 L990 7,8,9 2009 SR-823/Red Road FDOT $ 4,277,434.47 Miami-Dade/Broward County Line to Revised 4/23/12(se) Packet Page -846- nom 2/12/2013 11 .D. 0 I. COMMUNITY ASPHALT CORP. SHEET 1NO. z - Community From 2007 to 2011 Asphalt Contracts Completed Within The Past Five Years 5992 5,7,9 2007 N-.-Roosevelt Charley Toppinos&Sons $; 103,22 40 5995 6,7,8,9 2009 FDOT#413796-1-52-01; SR-817 FDOT 3 10,345,958.38 . 5997 7,8 2008 Bayhill Estates Sonic Engineering, Inc. 5 2254 WO I . 5999 6,7,8 2008 Key West Steam Charley Toppinos&Sons S 107.384.00 FDOT#249856-4-52-01; E6E39 , 6000 7,8 2011 Reconstruction of SR-5(US-1)South FDOT $ 103,114659 s From MP 356 to SW 344 Street a ,,, � 6001 7,8 2008 Croissant Park Conquest Engineering $ 7' 01,180.00 6005 6,7,8 2008 FDOT#418100-1-52-01 FDOT S 2.703,581r171 Cudjoe Key I 6010 7,8,9 2008 PBC Fire Rescue & B &B Underground S 342,701.001 Administration Bldg 6015 5,6,7 2008 Village of Oriole Plaza Federal Maintenance, Inc. S 137,813.50 7215 Atlantic Avenue, Delray Beach 6024 6,7,8 2008 Lowes St. American Engineering& S 536;779.80 Lucie County&Cashmere Development . , i j 6025 6,7,8 2009 FDOT#228160-1-52-01 FDOT $ 6.224,648.79 SR-820 6027 5,6 2008 Village Parkway Phase 1A Felix Associates, LLC. S 410,350.00 Port St Luice 6029 7,8 2009 BDG Kendall Rock Power Paving $ 124,486.00 6030 `, 6,7,9 2009 Gleneagles Country Club Gleneagles Country Club 5 1,229,179.37 Forest Hill Boulevard Rosso Paving &Drainage, Inc. 5 322,898.70 6031 8,9 2009 From Wellington Trace to SR-80 g g Yamato Road (PBC Prg#2003504B) 6032 7,8 2008 From a PT West of Cain Blvd to a PT W Rosso Paving &Drainage, Inc $ 298,342.80 of SR-7 Revised 4/23/12(se) Packet Page -847- 2/12/2013 11 .D. SHEET NO. OHL COMMUNITY ASPHALT CORP. 7 (11) Community From 2007 to 2011 .` ., Asphalt Contracts Completed Within The Past Five Years { 7,8 2009 Michael's Creek W.Jackson& Sons e i r s ,''''.-5':',,,,,,,„0„t ,,,.., , ,,,,.. ., „..,,,,,,,,,,,,:„,„„,,,, ,...„:„..„,„ ,,,,,,,,,,.,,,t-- FDOT#413795-1-52-01 FDOT ( i 5 0 6,7,8 2009 a SR-816 87,8 2008 Shark Key Wastewater ADB Utility Contractors ,„ .t99 '9d,. r}� y_ xa3 4 a o s 6Q49 5,6,7 2009 Middle School, 57th and 58th Avenue Joe Bear, Inc $ ,a44 4,4: s',44.',''''.t. . �}pp tM1 FDOT#413886-1-52-01 2$ ,", , 0S>a 7,8,9 2009 SR 816/Oakland Park Boulevard from FDOT 1 X107 �M1;� :; SR-7/US-44 to east of NW 31st Ave � ' ,� i yl FDOT#414635-1-52-01;T6122 �6O 5 6,8,9 2010 SR-90 (US-41/Tamiami Trail)From 10 FDOT � 0=^''-:"..:17.4,1,,,, � „, Miles E of Collier Co. Line g South Road Medical Offices 6S$F:' 5,6 2009 Rio-Back Corp. ' SW Corner of 50th and SR-7 7 4 / FDOT#419658-1-52-01 �ti 6i�6�1 7 8 2009 SR-90(US 41/Tamiami Trail) FDOT $rt" � e a O ", 16544 6,7,8,9 2008 Street Improvements 2008 City of Boca Raton �y 4 $'? 7,8 2009 Segovia Lakes Sonic Engineering, Inc. � � �� t ` Lauderdale Marine CTR i0£9 7&8 2008 Expert Evacuation SR 84 and 95 . � � ' ; Treasure Coast Public Safety Complex � ,u � 6�- 8,9 2009 SPS Contracting, Inc. $ ` �, Kirby Loop Road, Ft.pierce '- r Y P P UM Serpentine Parking lot S0Z7 5&8 2008 Rock Power Paving m. S, ,,,,' S' 1635 Levant Ave.Coral Gables - w` Okeelanta 2008N ''54-7!71);;--i, 5,6,7 2008 Rio-Bak Corp �'� US-27 South Bay, FL ., 6980 7,8 2010 Village Parkway Felix Associates F i.yam , 4O _3 ,. - Sadowski Causeway Roadway Repair& 6 e , 7,8 2009 City of Key Colony Beach _", Resurfacing °\x >, , . . Revised 4/23/12(se) Packet Page-848- N OHS COMMUNITY ASPHALT CORP. SHEET NO. 7 (12) q t R� a y Community From 2007 to 2011 Asphalt Contracts Completed Within The Past Five Yea rs 2/12/2013 11 .D. 6087 7,8 2008 Reuse Water Distribution Conquest Engineering e{i FDOT# 169869-2-52-01 ' 6090.1 8,9 2009 SR-700(US-98) North of SR-70 to NW FDOT g , 80th Street 6094 5,6 2009 Port Mayaca PH2 Felix Associates, LLC S 124p7 i 0, , R y 7,8 2008 Great Florida Bank Arrow Asphalt S 107,630.75 ( 6099 5,7,8 2008 NE 171st St and NE 22nd Ave Arrow Asphalt S 170,397.15 6101 5,7,8 2009 Publix American Engineering& S 310,379.00 i,. Development 6104 I 7.8 2009 Silver Palms RV Resort(US-1) Optimum Services, Inc. , S 282,332.20 1 . i 6105 7,8 2010 Annual Asphalt Fiscal 2010 Palm Beach County $ 8.220,;97.00 6106 8,9 2009 Cross Town 1-95 interchange Johnson Brothers, Inc. $ 1,942,522.06 6109 5,6 2008 Hilton in Miami International Airport Atlantic Southern Paving $ 124,989.00 6110 7,8 2010 Primary Asphalt Concrete Pavement City of Port St. Lucie S 2,993,265.00 FDOT#241211-1-52-01 6111 6,8,9 2010 Lucas Marine $ 301.388.00 Turkey Creek Bridge 6115 5,6 2009 Becker Road,Segment 1 Johnson Brothers, Inc. $ 2..93,442.11 FDOT#416242-1-52-01 6120 6,7,8,9 2010 FDOT 0, 8,982,297.65 SR-25(US-27) 6122 8,9 2009 Stack Crossing, Palm Bay Road Palm Bay Venture $ 36,431.84 612S. 7,8 2009 Province Bay 2nd lift Indian River Blvd. Sonic Engineering, Inc. S 29,646.80 Revised 4/23/12(se) Packet Page-849- 2/12/2013 11 .D. °''" O N L COMMUNITY . 7 (13) SHEET N O. ASPHALT CORP < `�� : ' ` Community From 2007 to 2011 '" Asphalt Contracts Completed Within The Past Five Years d FDOT#418090 1 52 01;T6165 � f BR-9l3(NW 87th Avenue) ,.1,,,, 01,i,.4:,1,,.. 5,6 2009 From North of West Flagler Street A Pt s FDOT ,. �� of NW 12th Street '_ 1 � 5,6 2009 Coral Gate Condos Asphalt Paving of South Florida g' W litiViAti.g4:Zi ��' FDOT#415315-1-52-01 ` �� 4 ', 6,7,8,9 2010 SR-80 FDOT its t 6131 " 6,7 2009 Hurricane Contracts 2008 FDOT '7, a its 7,8 2009 Imperial Point/Medical Arts Central Florida Equipment Rentals 12 �Y ' Inc. r }m 4' x'1{ 11, ' 134 5,6 2009 Homewood Blvd. Bike Lanes Rosso Paving &Drainage, Inc ,' p 613 6,7,8,9 2010 FDOT#415291-1-52-01 FDOT SR-5(US-1) �1 6a�1© ;� 7,8 2009 Big Cypress Airport Seminole Tribe of Florida "1 . 61x3 8,9 2009 City of Key West Waste Water Trans. D.N. Higgins Construction $ 8J 8 Saver Marine Operations 61 � 5,6 2009 Charley Toppinos& Sons Trumbo Annex Key West�5� f' 4 ':. Central Florida Equipment Rentals w 6131 5,5 2009 Leon Medical Center Inc. x6 -;" §aaF 6158 8,9 2009 Osceola Sugar Mill 2009 H&R of Belle Glade r="a u 69 - 7,8 2010 Suncoast High School PH-3B Optimum Services, Inc. a e FDOT#419856-1 52-01 �l.� � ., ,4 16t 6,7,8 2010 FDOT 916 . 165 7,8 2009 FDOT#426444-1-52-01l'$ FDOT r` Emergency Repairs � 5,6 2009 Palm Isles Subdivision Big D Paving % y ®o 7 8 2009 FDOT#422844-1-52-01 ,< L', SR-5(US-1} FDOT Rev ''j s Packet Page-850- 2/12/2013 11 .D. SHEET NO. °` O H L COMMUNITY ASPHALT CORP. 7 (14) S$ Community From 2007 to 2011 i�kK f is Asphalt Contracts Completed Within The Past Five Years 6171 6,7,8 2010 I-95 Culvert Improvements Brevard County $ 1,021 250:`"`- 6175 7,8 2010 FDOT#405578-4-52-01 FDOT $ 2,788,910.31' SR-112 6177 7,8 2010 Broadmoor Stormwater Utility DP Development S 712,949.00 Improvements jI FDOT#406094-4-52-01; E8J55 ''-`4:4l 1 6185 6,8,9 2011 SR-91 (Turnpike Mainline)From Peters FDOT $ `19,216,436.76 Road to Sunrise Boulevard 6189 6,7,8 2010 PB Gardens High School B& B Underground S 159,799.00 6190 7,8 2010 DRI Palm Bay Road Turn Lanes BMK Melbourne 35 Associates $ 264,385.68 r 4ir:4, 6201 6,8,9 2010 Millstone Landing Guettler&Sons $ 25,319.00 6203 7,8 2009 Pine Creek Sporting Club Guettler&Sons $ 175.664.30 6205 7,8 2010 FDOT#415323-1-52-01 SR FDOT $ 2,409,993.00 84 .' 6206 7,8,9 2009 Gulf Stream Water Main AKA Services �,�'' 113,152.00 6210 6,7,8 2010 FDOT#403596-2-52-01 FDOT $ 799,857.77 SR-60 6213 7,8 2009 Hobe Sound PC Turnlanes Advance Under 268,539.52 Project#2009-057 Pavement 6215 6,8,9 2010 and Resurfacing Various City of Boca Raton 1 5 500,237.41 Streets ! . 6216 _ 7,8 2010 Walton Road Felix Associates '6''S 1.288.381.59 6220 6,7,8 2010 FDOT#419648-1-52-01 FDOT $ 413,818.59 SR-811 6222 € 7,8 2011 Monroe Drive Utility Improvements Chaz Equipment $ 240,326.14 23 '' 7,8 2010 SE 4th Street B&B Underground Revd 4/231 (96.)B-°° Packet Page-851- 2/12/2013 11 .D. F, :,,,,,,, N OH COMMUNITY ASPHALT CORP. 7 ( I5) .! :. Community From 2007 to 2011 SHEET NO. Yt., `!_ Asphalt Contracts Completed Within The Past Five Years -5224- 2010- -Seaboard Terminal—Are: :. --.. Maytin-Engineering $ 247,2-37.00 6229 7.8 2010 Annual Asphalt Fiscal 2010 Indian River County $ 893.685.12 6230 6,7,8 2010 FDOT#415311-1-52-01 FDOT $ 2,192,732.00 SR-5(US-1) 6234 7,8 2010 Green River Parkway South Guettler&Sons $ 1,101.908.15 FDOT#415308-1-52-01;T4241 6235 7,8,9 2010 SR-808(Glades Road) From Boca Rio FDOT $ 3,666,664.91 Road to A Pt W of Renaissance Way 6238 7,8 2010 PBIA South Taxilane Improvements Rosso Paving and Drainage S 284,001,64 6239 7,8 2010 Strathmore Gate West Strathmore Gate West HOA S 176 1162.00 FDOT#419602-1-52-01/3-52-01 SR 6240`- 7,8,9 2010 821 FDOT $ 2.910,905.11 5245'' 7,8 2010 Airport Hanger Parking Area Seminole Tribe of Florida S 332,138.40 5252 6,7,8,9 2011 Wickham Road at NASA Boulevard & Palm Beach Grading 1;765,78719 Ellis Avenue 6253 7,8 2010 Flagler Avenue Improvements Charley Toppinos&Sons $ 273,188.75 6.255 7,8,9 2011 FDOT#426248-1-52-01 FDOT $ 2,010,812.88 20th Street 6;759 1 7,8 2010 Portofino Isles Port-o-Fino Isles a5 405,154.90 r6260 6,7,8,9 2010 FDOT#423517-1-52-01 FDOT $ 234,188.57 SR5 (US-1) 66261 7,8 2010 Auction House Florida Engineering and 261 241,027.90 Development FDOT#423553-1-52-01;T6169 FDOT#423553-2-52-01 6265 6,8,9 2011 FDOT#416853-1-52-01 FDOT $ 2,127,892.09 SR-5(Overseas Hwy) From Hwy MM.97 to MM100 Taxiway F Extension 6266-'-' 7,8 2010 PB1A,WPB, Florida Rosso Paving& Drainage Inc. $ 1,251 446 6270 6,7,8,9 2010 FDOT#416876-1-52-01 FDOT $ 1,056.713.15 SR-7(US-441) 6272 7,8 2010 City Of Vero Beach Force Main SPS Contracting, Inc. 0 . Revised 4/23/12(se) Packet Page -852- 2/12/2013 11 .D. SHEET NO. L.' OHL COMMUNITY ASPHALT CORP. 7 (16) ai x Community �,�. � From 2007 to 2011 ,._ : t_3.. Asphalt Contracts Completed Within The Past Five Years FDOT#427560-1-52-01; E4K94 .,:?f 011-- FDOT#-4 FDOT— 446,036.01 Soot Asphalt Re.air Prima Interstate FDOT#419849-1-52-01 FDOT 970.254.53 6280 6,8,9 2010 SR-5 <l , 6284 5,6,8,9 2011 FAU Innovations Apartments American Engineering 322,623.44 Boca Raton Development FDOT#415302-1-52-01;T4242 6285 6,8,9 2010 SR-76 (Port St. Lucie Blvd) From Florida FDOT 2,521;721.02 Tpk to Petunia Avenue ,I 6287:, 7,8 2010 Currie Park Develand Development S 115.293.00 4 ; s FDOT#416877-1-82-01 SR FDOT 3,070,576.82 6290 5,6,8,9 2010 7(US-441) 5294 1 7,8 2010 Port Mayaca Plantation Turn Lane Coastland Land Co $ 107,985.00 6303 8,9 2010 Annual Asphalt Fiscal 2010 Town of Palm Beach $ 232.337.64 630b-', 5,6,8,9 2011 FDOT#416905 1 52 01 FDOT $ 2411,680.59 SR-706(Indian Town Road) 6311 7,8 2010 Various Street Improvements Village of Wellington S 390,725.00 6316 6,7,9 2010 2976 PBC Central Reg Recycling Statewide Grading S 151,855.35 6317 7,8 2010 Christenson's Landing Ocean Gate General Contractors $ 126.216.40 American Engineering& $ 106,145.00 6319 6,8,9 2010 Garden Shops Publix Development FDOT#416877-1-52-01 FDOT $ 814,594.87 6320 6,7,8,9 2010 SR-7 (US-441) 6325 7,8 2010 Dykes Rd Resurfacing 2010 City of Pembroke Pines $ 244,400.00 6328 6,9 2010 Duda Farms Fiscal 2010 Duda Farms $ 257,929.00 6331 7,8 2010 Rolling Green Drainage Globetech Construction $ 429.073.15 6334 6,8,9 2010 SW 87th Avenue Progressive Pipeline, Inc. $ 191,393.00 FDOT#419852-1-52-01 6335 '" 6,9 2011 SR-934(71st Street)From Bay Drive FDOT $ 685,165.24 East to SR-A1A Collins Avenue 33rd Street and Poinsetta Avenue Utility 6338 8,9 2011 Foster Marine $ 136.246.63 Improvements Re sed 4/23;12(se) Packet Page -853- 2/12/2013 11 .D. 'c' OHL COMMUNITY ASPHALT CORP. SHEET NO. '' `' 7 (17) ti: Community From 2007 to 2011 . !i,' Asphalt Contracts Completed Within The Past Five Years _f�339 7 8 _ 2010_ Coconut Bnnaventi ira _Atlantic Southern Paving_ $" ' 3£i 065 00 . Roadway Repair and Resurfacing, at 6360 5,6,8,9 2011 The Village of Golf $ 510 979 ' various street locations *a rn 6361 6,8,9 2011 15th Avenue, Deerfield Beach West Construction Inc. $ 255,232.67 6379 8,9 2011 Commerce Center of Coconut Creek Miami-Dade County $ 228,153.95 6380 7,8 2011 Belvedere Road & Pike Road Palm Beach County Board of $ 248,469,56 Improvements County 6387 7,8,10 2011 Carriage Hills Drive Atlanttic Southern Paving $ 154280.00 FDOT#406095-8-52-01; E8K51 FDOT#406095-5-52-2 6395 5,6 2011 FDOT $ 3,267.738.24 Turnpike Main Milling &resurdacing, Miramar Parkway&Griffing Road , I 6403 7,8 2011 Sugar Mills 2011 Various Locations H&R of Belle Glade, Inc. $ 105.060.81 Pan American West NW 25th Street, 6414 8,9 2011 132nd Place& 137th Avenue Trans Florida $ 165,004.00 6415 5,6,8,9 2011 Forest Hill Boulevard, Section 3 H&J Contracting S 488,581.65 6416 7,8,9 2011 53rd Street(PH 2) & US-1, Vero Beach Ryan Golf Corporation S 441,398.26 6418 8,9 2007 3535 SW Kanner Hwy, Stuart 34994 Bride Meadows Farms S 191.928.61 FDOT#419602-1-52-01; E8J94 6420.; 7,8 2011 SR-821 Homestead Extension of FDOT S 544.182.51 Florida's Tunpike 6423 5,6 2011 Walton Road Widening from Village Sheltra&Son Construction $ 305,237.50 Green Drive to Leonard Road, St Lucie 51st Court(VB) 6452 7,8,10 2011 Ryan and Golf Corporation 8 146,151.22 Between 49th Street-55th Street 6604 7,8 2011 Roadway Improvements and Resurfacing Lee County Procurement at Various Locations Conuntrywide Management $ 183.552.69 5295-1 5,6,7,9 2007 Hallandale Beach Blvd Intersection Duo Hallandale $ 415.000.00 Revised 4/23/12(se) Packet Page -854- 2/12/2013 11 .D. STATE OF FLORIDA ill4i1 DE PARTMENT OF BUSINESS AND PROFESSIONAL REGULATION " .,-. CONSTRUCTION INDUSTRY LICENSING BOARD (850) 487-1395 x.44 ' 1940 NORTH MONROE STREET r.. TALLAHASSEE FL 32399-0783 FERNANDEZ, JOSE L COMMUNITY ASPHALT CORP 9725 NW 117 AVE SUITE 110 i MIAMI FL 33178 y STATE OF FLORIDA AC#6 20130 2 4 Congratulations! With this license you become one of the nearly one million ''--. DEPARTMENT OF BUSINESS AND Floridians licensed by the Department of Business and Professional Regulation. a _o PROFESSIONAL REGULATION Our professionals and businesses range from architects to yacht brokers,from -- boxers to barbeque restaurants,and they keep Florida's economy strong. C;0011475 07/18/22 120029337 Every day we work to improve the way we do business in order to serve you better - .. ."" A For information about our services,please log onto www.myfloridalicense.com. CERTIFIED GSNER�II ,CO„ KRACTOR , 1. There you can find more information about our divisions and the regulations that FERNANDEZ,. .JQSE L # -: impact you, subscribe to department newsletters and learn more about the COMMUNITY ASPHAL y 011i3' t Department's initiatives. Our mission at the Department is:License Efficiently,Regulate Fairly.We constantly strive to serve you better so that you can serve your customers. IS CERTIFIED under the provisions of Ch.489 rs Thank you for doing business in Florida,and congratulations on your new license! 6zpiratian date: AUG 31, 2014 1,12071800867 DETACH HERE _. t r' i • a§. ,t ',"'" . T10CDIVIENT+4ASACOLOREDBACKGROuND-*IetiPiliNT rsG±',LINENARK"'PATENTED PAPER AC# 6208024 STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD SECT#L12071800867 DATE BATCH NUMBER .LICENSE NBR 07/18/2012 120029337 1CGC011475 The GENERAL CONTRACTOR Named below IS CERTIFIED 4 A1 " .'t Under the provisions of Chapter 489 EIS,_ , i Expiration date: AUG 31, 2014 "' 't F .. ' �• t 'f Y' E' er Y � i.��` 3" �.e d. 1ZYb "6 P FERNANDEZ, JOSE L _ ,° _ COMMUNITY ASPHALT CORP lit'. �- 14005 N W 186TH STREET s,a ;. I . l e HIALEAH FL 33018 RICK SCOTT KEN LAWSON GOVERNOR , ' SECRETARY -. DISP' --- "— -- BY LAW ` ti _.______ Packet Page -855----____ 2/12/2013 11.0. ly�t STATE OF FLORIDA �"> . DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD (850) 487-1395 1940 NORTH MONROE STREET TALLAHASSEE FL 32399-0783 FERNANDEZ, JOSE L COMMUNITY ASPHALT CORP 9725 NW 117 AVE SUITE 110 MIAMI FL 33178 �. STATE OF FLORIDA AC#6 208 2 3 3 Congratulations! With this license you become one of the nearly one million ' "' DEPARTMENT OF BUSINESS AND Floridians licensed by the Department of Business and Professional Regulation. � yx a " PROFESSIONAL .REGULATION Our professionals and businesses range from architects to yacht brokers,from boxers to barbeque restaurants,and they keep Florida's economy strong. '0� CQC056789 c 3::FX12 120029336 Every day we work to improve the way we do business in order to serve you better.) For information about our services,please log onto www.myfloridalicense.com. CERT UNDERGROUND & EX,CAV CNTR There you can find more information about our divisions and the regulations that ! FERNANDEZ, JOSE L x impact you, subscribe to department newsletters and learn more about the COMMUNITY i,ASPHALT CORD Department's initiatives. - i Our mission at the Department is: License Efficiently, Regulate Fairly.We constantly strive to serve you better so that you can serve yourcustomers. IS CERTIFIED under the provieione of Ch.484 Fs Thank you for doing business in Florida,and congratulations on your new licenses ezt+ir:ctcn date: AUG'31, 2014 L12071EO1076 DETACH HERE s.;. ,THISDOCLI.ENT tiAS'A COLORED BACKGROUND.M,CROPRINTING-:LINEMARK'd'tYT NTEt7 Ai?Eii AC# 6208233 STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD SEQ#L12071801076 DATE BATCH NUMBER LICENSE NBR ? 1' 07/18/2012 120029336 CUC056799 The UNDERGROUND UTILITY & EXCAVATIONSCO Named below IS CERTIFIED Under the provisions of Chapter 489 FS Expiration date: AUG 31, - 2014 FERNANDEZ, JOSE L ,. COMMUNITY ASPHALT CORP. ' 14005 N W 186TH STREET'" HIALEAS FL 33018 RICK GOVERNOR SCOTT KEN LAWSON SECRETARY DISF Packet Page-856 BY LAW._._ c°uny 2/12/2013 11 .D. Lee County Tax Collector Tax Co fly, tor 2480 Thompson Street • Fort Myers, Florida 33901 sidle of S°A`am www.leetc.com Tel: (239) 533-6000 Local Business Tax Account: 1205281 Dear Business Owner: Your 2012-2013 Lee County Local Business Tax Receipt is attached below. The receipt is non- regulatory and is issued using the information currently on file with our office. It does not signify compliance with zoning, health or other regulatory requirements nor is it an endorsement of work quality. Annual account renewal notices are mailed in August to the address of record at that time;to ensure delivery of your annual notice,mailing addresses may be updated online at www.leetc.com. If there is a change in the business name, ownership, physical location or if the business is being closed, please follow the instructions on the back of this letter to transfer or to close the account. I hope you have a successful year. C14—/-1).14714- Ass* Lee County Tax Collector Detach and display bottom portion and keep upper portion for your records • sea CoU0fy LEE COUNTY LOCAL BUSINESS TAX RECEIPT 2012 - 2013 Tax Co for _ ACCOUNT NUMBER: 1205281 ACCOUNT EXPIRES SEPTEMBER 30, 2013 May engage in the business of: CERTIFIED GENERAL CONTRACTOR Location 16560 MASS CT FT MYERS FL 33912 THIS LOCAL BUSINESS TAX RECEIPT IS NON REGULATORY COMMUNITY ASPHALT CORP FERNANDEZ JOSE L THIS IS NOT A BILL-DO NOT PAY 9725 NW 117 AVE STE 110 MIAMI FL 33178 PAID 316752-1-1 09/19/2012 09:49 Af0k,. BXH1 $50.00 Packet Page-857- 2/12/2013 11 .D. CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with Community Asphalt Corporation ("Contractor") of 16560 Mass Court, Fort Myers Florida 33912, a Florida corporation, authorized to do business in the State of Florida, to perform all work ("Work") in connection with Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160), Bid No. 12-5948R ("Project"), as said Work is set forth in the Plans and Specifications prepared by Collier County Growth Management Division Transportation Engineering Department, the Engineer and/or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision, financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount"), in accordance with the terms of this Agreement: one million nine hundred and four thousand three hundred and forty four dollars ($1,904,344.00). Section 4. Bonds. A. Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit A, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise 28 12-5948R Immokalee Rd Paved Shoulders Packet Page-858- 2/12/2013 11 .D. acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www.fms.treas.gov/c570/c570.html#certified. Should the Contract Amount be less than $500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liquidated Damages. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The "Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within one hundred and eighty (180) calendar days from the Commencement Date (herein "Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within thirty (30) calendar days after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, one thousand one hundred forty eight dollars ($1,148.00) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all 29 12-5948R Immokalee Rd Paved Shoulders Packet Page-859- 2/12/2013 11 .D. actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion. The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract 30 12-5948R Immokalee Rd Paved Shoulders Packet Page-860- 2/12/2013 11 .D. Documents. Owner's recovery of any delay related damages under this Agreement Amok through the liquidated damages does not preclude Owner from recovering from Contractor any other non-delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement. Exhibit A: Performance and Payment Bond Forms Exhibit B: Insurance Requirements Exhibit C: Release and Affidavit Form Exhibit D: Contractor Application for Payment Form Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions Exhibit I: Supplemental Terms and Conditions Exhibit J: Technical Specifications Exhibit K: Permits Exhibit L: Standard Details (if applicable) Exhibit M: Plans and Specifications prepared by Transportation Engineering Dept. and identified as follows: Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge#030160) as shown on Plan Sheets 1 through 16. Exhibit N: Contractor's List of Key Personnel ITB 12-5948R Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge#030160) Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Julio F. Ordonez, P.E. Growth Management Division Transportation Engineering Department 2885 S. Horseshoe Drive Naples, Florida 34104 (239) 252-8260 (239) 252-5868 (Fax) 31 12-5948R Immokalee Rd Paved Shoulders Packet Page-861- 2/12/2013 11 .D. B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E- mail or Facsimile, addressed to the following: Manuel Aguiar, Vice President Community Asphalt Corporation 16560 Mass Court Fort Myers, FL 33912 (239) 337-9486 (239) 337-9488 Fax C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreement. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. • Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a 32 12-5948R Immokalee Rd Paved Shoulders Packet Page-862- 2/12/2013 11.D. waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's Purchasing Policy and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions. To the extent any conflict in the terms of the Contract Documents cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. **** 33 12-5948R Immokalee Rd Paved Shoulders Packet Page-863- 2/12/2013 11 .D.. IN WITNESS WHEREOF, the parties have. executed this Agreement on the date(s) indicated below. CONTRACTOR: TWO WITNESSES: Community Asphalt Corp. By: - FIRST WITNESS Type/Print Name and Title Type/Print Name SECOND WITNESS Type/Print Name Date: OWNER: ATTEST: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY FLORIDA Dwight E. Brock, Clerk BY: BY: , Chair Approved As To Form and Legal Sufficiency: Print Name: Assistant County Attorney .�. • I _ 34 12-5948R immokalee Rd Paved Shoulders Packet Page-864- __ ... 2/12/2013 11 .D. EXHIBIT A 1: PUBLIC PAYMENT BOND Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160) Bond No. Contract No. 12-5948R KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and , as Surety, located at (Business Address) are held and firmly bound to as Obligee in the sum of ($ ) for the payment whereof we bind ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of 20 with Obligee for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this day of 20 , the name of each party being affixed and these presents duly signed by its under-signed representative, pursuant to authority of its governing body. 35 12-5948R Immokalee Rd Paved Shoulders Packet Page-865- 2/12/2013 11 .D. Signed, sealed and delivered in the presence of: PRINCIPAL BY: Witnesses as to Principal NAME: ITS: STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature of Notary) NAME: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commission No.: ATTEST: SURETY: (Printed Name) (Business Address (Authorized Signature) Witnesses to Surety (Printed Name) 36 12-5948R Immokalee Rd Paved Shoulders Packet Page-866- 2/12/2013 11 .D. OR Adotifit As Attorney in Fact (Attach Power of Attorney) Witnesses (Printed Name) (Business Address) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of , 20 , by , as of Surety, on behalf of Surety. He/She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (Signature) Name: (Legibly.Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: 37 12-5948R Immokalee Rd Paved Shoulders Packet Page-867- 2/12/2013 11 .D. EXHIBIT A 2: PUBLIC PERFORMANCE BOND Immokalee Road Paved Shoulder Improvements (Shady Hollow Blvd to 1/4 Mile E of Bridge #030160) Bond No. Contract No. 12-5948R KNOW ALL MEN BY THESE PRESENTS: That , as Principal, and as Surety, located at (Business Address) are held and firmly bound to , as Obligee in the sum of ($ ) for the payment whereof we bond ourselves, our heirs, executors, personal representatives, successors and assigns, jointly and severally. WHEREAS, Principal has entered into a contract dated as of the day of , 20 , with Obligee for in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the Contract at the times and in the manner prescribed in the Contract; and 2. Pays Obligee any and all losses, damages, costs and attorneys' fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay damages, whether liquidated or actual, incurred by Obligee; and 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this Bond. The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the terms of the Contract or to work or to the specifications. 38 12-5948R Immokaiee Rd Paved Shoulders Packet Page-868- 2/12/2013 11 .D. This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section , 255.05, Florida Statutes, shall not apply to this bond. In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of this Performance Bond regardless of the number of suits that may be filed by Obligee. IN WITNESS WHEREOF, the above parties have executed this instrument this day of , 20 , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. Signed, sealed and delivered in the presence of: PRINCIPAL BY: Witnesses as to Principal NAME: ITS: STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of , 2 0 , b y as of , a corporation, on behalf of the corporation. He/she is personally known to me OR has produced as identification and did (did not) take an oath. My Commission Expires: (Signature) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: 39 12-5948R Immokalee Rd Paved Shoulders Packet Page-869- 2/12/2013 11 .D. ATTEST: SURETY: (Printed Name) (Business Address) (Authorized Signature) Witnesses as to Surety (Printed Name) OR As Attorney in Fact (Attach Power of Attorney) Witnesses (Printed Name) (Business Address) (Telephone Number) STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of 20 , by , as of a Surety, on behalf of Surety. He/She is personally known to me OR has produced as identification and who did (did not) take an oath. My Commission Expires: (Signature) Name: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of: Commission No.: 40 12-5948R Immokalee Rd Paved Shoulders Packet Page-870- 2/12/2013 11 .D. EXHIBIT B: INSURANCE REQUIREMENTS The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein, except such rights as they may have to the proceeds of such insurance. The Vendor and County shall, where appropriate, require similar waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number and title. Aimu The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Vendor has any self-insured retentions or deductibles under any of the below listed minimum required coverage, Vendor must identify on the Certificate of Insurance the nature and amount of such self- insured retentions or deductibles and provide satisfactory evidence of financial 41 12-5948R Immokalee Rd Paved Shoulders Packet Page -871- 2/12/2013 11 .D. responsibility for such obligations. All self-insured retentions or deductibles will be Vendor's sole responsibility. Coverages shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitation,whichever is longer. The Vendor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non-renewal on the part of the insurance carrier or the Vendor. The Vendor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder, Vendor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverages required herein, the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the Vendor for such coverages purchased. If Vendor fails to reimburse the County for such costs within thirty (30) days after demand, the County has the right to offset these costs from any amount due Vendor under this Agreement or any other agreement between the County and Vendor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverage(s) shall in no way be construed to be a waiver of any of its rights under. the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 42 12-5948R Immokalee Rd Paved Shoulders Packet Page-872- 2/12/2013 11 .D. Collier County Florida Insurance and Bonding Requirements tnsurance1 Bond;Type ` . Required Lb its ,"A.n ` ° ` , rcr 1. ®Worker's Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Compensation Statutory Limits and Requirements 2. ® Employer's Liability $1,000,000 single limit per occurrence 3. ® Commercial General Bodily Injury and Property Damage Liability (Occurrence Form) patterned after the current $1,000,000 per occurrence, $2,000,000 aggregate for Bodily Injury Liability ISO form and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. ® Indemnification To the maximum extent permitted by Florida law, the ContractorNendor/ Consultant shall indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the ContractorNendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 4. ® Automobile Liability $ 1.000.000 Each Occurrence; Bodily Injury & Property Damage, Owned/Non-owned/Hired; Automobile Included 5. ❑ Other insurance as ❑Watercraft $ Per Occurrence noted: ❑ United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑ Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. $ Per Occurrence ❑Aircraft Liability coverage shall be carried in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. $ Per Occurrence ❑ Pollution $ Per Occurrence ❑ Professional Liability $ per claim and in the aggregate • $1,000,000 per claim and in the aggregate • $2,000,000 per claim and in the aggregate ❑ Project Professional Liability $ Per Occurrence otolklk 43 12-5948R Immokalee Rd Paved Shoulders Packet Page-873- 2/12/2013 11 .D. o. ® Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the County Clerk, or proposal bond in a sum equal to 5%of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 7. ® Performance and For projects in excess of$200,000, bonds shall be submitted with the Payment Bonds executed contract by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall be rated as"A-"or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 8. ® Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Vendor shall provide County with certificates of insurance meeting the required insurance provisions. 9. ® Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. 10. f:4 The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 11. ® Thirty (30) Days Cancellation Notice required. • Vendor's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five (5) days of the award of this solicitation. Name of Firm Date Vendor Signature Print Name Insurance Agency Agent Name Telephone Number 44 12-5948R Immokalee Rd Paved Shoulders Packet Page -874- 2/12/2013 11 .D. EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF COLLIER ) STATE OF FLORIDA ) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ paid, ("Contractor") releases and waives for itself and it's subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner dated , 20 for the period from to , excluding all retainage withheld and any pending claims or disputes as expressly specified as follows: (2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, have been fully satisfied and paid. (3) To the maximum extent permitted by law, Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No. CONTRACTOR BY: ITS: President DATE: Witnesses STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of , 20 , by , as of , a corporation, on behalf of the corporation. He/she is personally known to me or has produced as identification and did (did not)take an oath. My Commission Expires: (Signature of Notary) NAME: (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Commissioner No.: 45 12-5948R Immokalee Rd Paved Shoulders Packet Page-875- 2/12/2013 11 .D. EXHIBIT D: FORM OF CONTRACT APPLICATION FOR PAYMENT (County Project Manager) Bid No. (County Department) Project No. Collier County Board of County Commissioners(the OWNER) or Purchase Order No. Collier County Water-Sewer District(the OWNER) Application Date FROM: (Contractor's Representative) Payment Application No. (Contractor's Name) for Work accomplished through the Date: (Contractor's Address) RE: (Project.Name) Original Contract Time: Original Contract Price: $ Revised Contract Time: Total Change Orders to Date $ Revised Contract Amount $ Total value of Work Completed Retainage @ 10% thru [insert date] $ and stored to Date $ Retainage @ _% after [insert date] $ = Less Retainage $ Total Earned Less Retainage $ Less previous payment(s) $ Percent Work completed to Date: % AMOUNT DUE THIS Percent Contract Time completed to Date % APPLICATION: $ Liquidated Damages to be Accrued $ Remaining Contract Balance $ ATTACH SCHEDULE OF VALUES AND ACCOMPANYING DOCUMENTATION TO THIS APPLICATION CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment numbered 1 through inclusive; (2)title to all materials and equipment incorporated in said Work or otherwise listed in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims, security interests and encumbrances(except such as covered by Bond acceptable to OWNER); (3)all amounts have been paid for work which previous payments were issued and received from the OWNER and that current payment is now due; and (4) CONTRACTOR has only included amounts in this Application for Payment properly due and owing and CONTRACTOR has not included within the above referenced amount any claims for unauthorized or changed Work that has not been properly approved by Owner in writing and in advance of such Work. By CONTRACTOR: (Contractor's Name) (Signature) DATE: (Type Name &Title) (shall be signed by a duly authorized representative of CONTRACTOR) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended: By Design Professional : (DP's Name) (Signature) DATE: (Type Name &Title) Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved: By OWNER'S Project Manager: (Signature) DATE: (Type Name and Title) 46 12-5948R Immokalee Rd Paved Shoulders Packet Page-876- • 2/12/2013 11 .D. CD �iz,9 0 o �II3 °' m yin _3 m ca 11.1 O Iat a e coi as 2 I1- 0 d E c U W O a) a) -• Q e cS I- c Q' O � . H 4) CIS c U CO N Z Z N - LL l6 PQ < CD m O N G C 0 2 F- 15 W J m 'O Z• a E [a a o 0 " U �,m -I H W H f o Q W Q' Q C I- -I0p 0 Ct Q2 in 0 O H _c ` ° UelS - c . W Q c c z K p 7 � U) Q E I2 O N O CI� E 0 W d .13 I-IW y m J o m 0 rL c Q a a FW- —'3 d LL d Z Q a O O p 0 m W • a v _c m Y -I y o' c D p a � a I N o �' O p < c cu N w F- CO L .c 0 re F I- U . \° o O C d W . .I f• I 0 O J ti m 2 > <-OO i C .c a) a) _ o a) '5oc o a) o c_-o a 0 a) CD c o ire zI_ a) U `° N U) J U y a) a) 0 p 'ala o c i- .c m v E olU) a) _ _ _°,_ m- CO CD E j 7 L CD I- m iW - �c >+� 9) II a- glm m n) s N ▪ Wi r TO X E ~ z �c't IL a. I Packet Page-877- —' 2/12/2013 11 .D. co o I- w c • c co CO w o u d g ❑ ❑ wet. co) U .! I- to + > < N d U D co N C LL �' d •� > of m 'd a a (0 as 73 m Q 0 'm d a. m a - L N L ✓ 0 O G > Z L 0) o. N i a7 0 0 CD Q. � 7 L -0 a) C as a)o m a U ce ❑ a� To Y a7 co Q. co Packet Page-878- 2/12/2013 11 .D. EXHIBIT E: CHANGE ORDER TO: FROM: Collier County Government Project Name: Construction Agreement Dated: Bid No. : Change Order No.: Date: Change Order Description Original Agreement Amount $ Sum of previous Change Orders Amount $ This Change Order Amount Revised Agreement Amount $ Original Contract Time in calendar days Adjusted number of calendar days due to previous Change Orders This Change Order adjusted time is Revised Contract Time in calendar days Original Notice to Proceed Date Completion date based on original Contract Time Revised completion date Contractor's acceptance of this Change Order shall constitute a modification to the Agreement and will be performed subject to all the same terms and conditions as contained in the Agreement, as if the same were repeated in this acceptance. The adjustments, if any, to the Agreement shall constitute a full and final settlement of any and all claims of the Contractor arising out of or related to the change set forth herein, including claims for impact and delay costs. Prepared by: Date: Project Manager Recommended by: Date: Design Professional Accepted by: Date: Contractor Approved by: Date: Department Director Approved by: Date: Division Administrator Approved by: Date: Purchasing Department Authorized by Date: Director (For use by Owner: Fund Cost Center: Object Code: Project Number: ) • 49 12-5948R Immokalee Rd Paved Shoulders Packet Page-879- 2/12/2013 11 .D. EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. Design Professional's Project No. PROJECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER And To Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 50 12-5948R lmmokalee Rd Paved Shoulders Packet Page-880- 2/12/2013 11 .D. RESPONSIBILITIES: OWNER: CONTRACTOR The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20 Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER By: Type Name and Title 51 12-5948R Immokalee Rd Paved Shoulders Packet Page-881- 2/12/2013 11.D. EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: Date: , 20 Contractor: The following items have been secured by the for the Project known as and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days. Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner(attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As-Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14. Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: (Company Name) (Signature) (Typed Name &Title) By Design Professional: (Firm Name) (Signature) (Typed Name&Title) By Owner: (Department Name) (Signature) (Name &Title) 52 12-5948R Immokalee Rd Paved Shoulders Packet Page-882- 2/12/2013 11 .D. EXHIBIT H: GENERAL TERMS AND CONDITIONS 1. INTENT OF CONTRACT DOCUMENTS. 1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and installed as part of the Work, whether or not called for by the Contract Documents. 2. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work-site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions; equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 53 12-5948R Immokalee Rd Paved Shoulders Packet Page-883- 2/12/2013 11 .D. 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub-Section 2.2 as the "Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven (7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance, the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. 3. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be .a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will 54 12-5948R Immokalee Rd Paved Shoulders Packet Page-884- 2/12/2013 11 .D. generally be limited to the hours of 7:00 a.m. to 5:00 p.m., Monday through Friday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Contractor shall submit all Applications for Payment to the County's Project Manager and/or designee. 4.4 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.5 Contractor shall submit six (6) copies of its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner (which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing, the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218.735, F.S. and the administrative procedures 55 12-5948R Immokalee Rd Paved Shoulders Packet Page-885- 2/12/2013 11 .D. established by the County's Purchasing Department and the Clerk of Court's Finance Department respectively. In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re-submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent (10%) of the portion thereof approved by the Project Manager for payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent (50%) completion subject to the guidelines set forth in Florida Statute 255.078 and as set forth in the Owner's Purchasing Policy. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub-subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub-subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule, which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 56 12-5948R Immokalee Rd Paved Shoulders Packet Page-886- 2/12/2013 11.D. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County shall not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 5. PAYMENTS WITHHELD. 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non-compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or(g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non-liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5.3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off-set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Purchasing Department and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative.and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the 57 12-5948R Immokalee Rd Paved Shoulders Packet Page-887- 2/12/2013 11 .D. Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 7. SUBMITTALS AND SUBSTITUTIONS. 7.1 Contractor shall carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method, technique, sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will 58 12-5948R Immokalee Rd Paved Shoulders Packet Page-888- 2/12/2013 11 .D. be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special u , performance guarantee or other surety with respect to any substitute. The Project Manager will record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub-Contractor's personnel; 8.1.4 The number of Contractor's and Sub-Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1.8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change 59 12-5948R Immokalee Rd Paved Shoulders Packet Page -889- 2/12/2013 11 .D. Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features (e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The "As-Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to Contractor's entitlement to final payment, these "As-Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later. Owner, or any duly authorized agents or representatives of Owner, shall have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the document retention period noted above; provided, however, such activity shall be conducted only during normal business hours. 9. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material-men, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 60 12-5948R Immokalee Rd Paved Shoulders Packet Page-890- 2/12/2013 11 .D. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work Directive Change. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these I Conditions or Aft, else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount, the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change (including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all overhead and profit for all Subcontractors' and sub-subcontractors' direct labor and material costs and actual equipment costs shall be permitted, with a maximum five percent (5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or sub-subcontractor for field and home office overhead is included in the markups noted above. Contractor's and Sub-Contractor's bond costs associated with any change order shall be included in the overhead and profit expenses and shall not be paid as a separate line item. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 61 12-5948R Immokalee Rd Paved Shoulders Packet Page-891- 2/12/2013 11 .D. 10.7 Any modifications to this Contract shall be in compliance with the County Purchasing Policy and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty- eight (48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pendency of any Claim. 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight (48) hours of being notified of the other work. If the Contractor fails to send the above required forty- eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is'performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it 62 12-5948R Immokalee Rd Paved Shoulders Packet Page -892- 2/12/2013 11 .D. unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Jaw Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, Contractor shall indemnify and hold harmless Owner and its officers and employees from any and all liabilities, claims, damages, penalties, demands, judgments, actions, proceedings, losses or costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, whether resulting from any claimed breach of this Agreement by Contractor, any statutory or regulatory violations, or from personal injury, property damage, direct or consequential damages, or economic loss, to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 13 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in Exhibit B to the Agreement. Further, the Contractor shall at all times comply with all of the terms, conditions, requirements and obligations set forth under Exhibit B. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, worker's compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 63 12-5948R Immokalee Rd Paved Shoulders Packet Page-893- 2/12/2013 11 .D. • 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet-based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: • Commodity based procurement where no services are provided. • Where the requirement for the affidavit is waived by the Board of County Commissioners Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Vendors are also required to provide the Collier County Purchasing Department an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the Bidder does not comply with providing both the acceptable E-Verify evidence and the executed affidavit the bidder's proposal may be deemed non- responsive. Additionally, vendors shall require all subcontracted vendors to use the E-Verify system for all purchases not covered under the "Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (E-Verify) program visit the following website: http://www.dhs.gov/E-Verifv. It shall be the vendor's responsibility to familiarize themselves with all rules and regulations governing this program. Vendor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s) - to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2.3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent 64 12-5948R Immokalee Rd Paved Shoulders Packet Page-894- 2/12/2013 11 .D. in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies when the Contractor is acquiring permits. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. 18.1 Contractor shall be considered in material default of the Agreement and such default shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents within the time specified herein; or (2) fails to properly and timely perform the Work as directed by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of the Work; or (5) fails to resume Work which has been suspended within a reasonable time after being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10) days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s) within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion, then Owner, at its option, without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses 65 12-5948R Immokalee Rd Paved Shoulders Packet Page-895- 2/12/2013 11 .D. (including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials, equipment, supplies, and other items therefor or re-letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein, then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below. 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen (14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or 66 12-5948R Immokalee Rd Paved Shoulders Packet Page-896- 2/12/2013 11 .D. any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work(or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefor. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch-list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site (or designated portion thereof) after the date of Substantial Completion, but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch- list. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly issue a final Certificate for Payment, recommending that, on the basis of their observations and inspections, and the Contractor's certification that the Work has been completed in accordance with the terms and conditions of the Contract Documents, that the entire balance found to be due Contractor is due and payable. Neither the final payment nor the retainage shall become due and payable until Contractor submits: (1) Receipt of Contractor's Final Application for Payment. (2) The Release and Affidavit in the form attached as Exhibit C. (3) Consent of surety to final payment. (4) Receipt of the final payment check list. (5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or materialmen supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance 67 12-5948R Immokalee Rd Paved Shoulders Packet Page-897- 2/12/2013 11 .D. with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner, Design Professional, their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection, testing or approval. All inspections, tests or, approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re-inspection fees and costs; to the extent such re-inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period 68 12-5948R Immokalee Rd Paved Shoulders Packet Page-898- 2/12/2013 11 .D. beyond the regular eight (8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shall as directed, either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non-defective Work. Contractor shall bear all direct, indirect and consequential costs of such correction or removal (including,. but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be. observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstruction. 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the 69 12-5948R Immokalee Rd Paved Shoulders Packet Page-899- 2/12/2013 11 .D. Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice, to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent, who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractors representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit N is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractors work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the - liquidated damages described in Section 5.B, for services not rendered. 25. PROTECTION OF WORK. 25.1 Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or any one for whom 70 12-5948R Immokalee Rd Paved Shoulders Packet Page-900- 2/12/2013 11 .D. Contractor is legally liable for is responsible for any loss or damage to the Work, or other work or materials of Owner or Owner's separate contractors, Contractor shall be charged with the Amok same, and any moneys necessary to replace such loss or damage shall be deducted from any amounts due Contractor. 25.2 Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 25.3 Contractor shall not disturb any benchmark established by the Owner or Design Professional with respect to the Project. If Contractor, or its subcontractors, agents or anyone for whom Contractor is legally liable, disturbs the Owner or Design Professional's benchmarks, Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight (48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 71 12-5948R Immokalee Rd Paved Shoulders Packet Page-901- 2/12/2013 11 .D. 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 72 12-5948R Immokalee Rd Paved Shoulders Packet Page-902- 2/12/2013 11 .D. 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5.7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5.9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend a pre-construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre-construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right-of-Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as prescribed in the Florida Department of Transportations Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management. The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway & Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 73 12-5948R Immokalee Rd Paved Shoulders Packet Page-903- 2/12/2013 11 .D. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work ("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall assign to Contractor any and all warranties and Contract rights Owner may have from any manufacturer or supplier of any such Direct Purchase by Owner. 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any 74 12-5948R Immokalee Rd Paved Shoulders Packet Page-904- 2/12/2013 11 .D. portion of the Work on this Project must be "qualified" as defined in Collier County Ordinance 87-25, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project. The list identifying each Subcontractor cannot be modified, changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self-performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub-subcontractor performing any portion of the Work, as well as maintain a log of all such licenses. All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of Owner upon termination of Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third-party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its sub-subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on- site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor (including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be caused by Owner or Design Professional or attributable to Owner or Design 75 12-5948R Immokalee Rd Paved Shoulders Packet Page-905- 2/12/2013 11 .D. Professional and including claims based on breach of contract or negligence, shall be an extension of its contract time. 33.6.2 In the event of a change in the work, the Subcontractor's claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus no more than 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub- subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner, and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 34.1.3 Shop Drawing Submittal/Approval Logs 34.1.4 Equipment Purchase/Delivery Logs 34.1.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 34.1.10 Equipment Costs 34.1.11 Cost Proposal Request 34.1.12 Payment Request Records 34.1.13 Meeting Minutes 34.1.14 Cost-Estimates 34.1.15 Bulletin Quotations 34.1.16 Lab Test Reports 34.1.17 Insurance Certificates and Bonds 34.1.18 Contract Changes 34.1.19 Permits 34.1.20 Material Purchase Delivery Logs 34.1.21 Technical Standards 34.1.22 Design Handbooks 34.1.23 "As-Built" Marked Prints 34.1.24 Operating & Maintenance Instruction 34.1.25 Daily Progress Reports 34.1.26 Monthly Progress Reports 34.1.27 Correspondence Files 34.1.28 Transmittal Records 76 12-5948R Immokalee Rd Paved Shoulders Packet Page -906- 2/12/2013 11.D. 34.1.29 Inspection Reports 34.1.30 Punch Lists 34.1.31 PMIS Schedule and Updates 34.1.32 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the presentation requirements and format. Presentations may include, but not be limited to, the following information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. If required, Vendor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Department for all employees that shall provide services to the County under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 37.VALUE ENGINEERING. All projects with an estimated cost of $10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A "project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of $2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. An underground 62-761, Florida Administrative Code (F.A.C.) or aboveground 62-762, F.A.C. regulated tank requires notification to the `County' prior to installation or closure of the tank. The Pollution Control Department (239-252-2502), via contract GC-690 with the Florida Department of Environmental Protection (FDEP), is the County (local program) for the purposes of these rules. Regulated tanks require notification to the `county' local program thirty (30) days prior to and again forty-eight (48) hours prior to commencement of the installation. Closure 77 12-5948R Immokalee Rd Paved Shoulders Packet Page-907- 2/12/2013 11 .D. activities require a ten (10) day notification and then a forty-eight (48) hour notification prior to commencement. The notification is to allow for scheduling of the inspections pertaining to the installation/closure activities. A series of inspections will be scheduled based upon system design after discussing the project with the contractor/project manager. Specifics on applicability, exemptions, and requirements for regulated pollutant storage tank systems can be found in 62-761, F.A.C. and 62-762, F.A.C. or you may contact the Pollution Control Department with your questions. Please note that equipment must be listed on the FDEP approved equipment list and will be verified at inspection along with installation and testing procedures. The approved equipment list is constantly updated and can be found at the FDEP Storage Tank Regulation website along with rules, forms and other applicable information. 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached during negotiations to OWNER for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached at mediation to OWNER'S board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 78 12-5948R Immokalee Rd Paved Shoulders Packet Page-908- 2/12/2013 11 .D. EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS Supporting documents found at: http://bid.colliergov.net/bid/ ANNO 79 12-5948R Immokalee Rd Paved Shoulders Packet Page-909- 2/12/2013 11 .D. EXHIBIT J: TECHNICAL SPECIFICATIONS Supporting documents found at: http://bid.colliergov.net/bid/ 80 12-5948R Immokalee Rd Paved Shoulders Packet Page-910- 2/12/2013 11 .D. iw EXHIBIT K: PERMITS ''" Supporting documents found at: http://bid.colliergov.net/bid/ 81 12-5948R Immokalee Rd Paved Shoulders Packet Page -911- 2/12/2013 11 .D.'' SOUTH FLORIDA WATER MANAGEMENT DISTRICT e T.oWER WEST COAST REGIONAL SERVICE CEnrrER 2301 McGregor Boulevard,Fort Myers,FL33901 i '' (239)338-2929.800-248-1201 •Suncom 748-2929•Fax(239)3338-2936•www.sfwmd.gov/Iwc/ Environmental Resource Regulation Application No.: 110728-1 August 23,2011 COLLIER COUNTY BOARD OF COUNTY COMMISSIONERS 3310 TAMIAMI TRAIL EAST NAPLES, FL 34112 Dear Permittee: SUBJECT: EXEMPTION MODIFICATION NO.: 11-03272-P Project : IMMOKALEE ROAD PAVED SHOULDERS Location: Collier County, S22,23,24,25,26,27,34,35/T47S/R27E S2,3,20, 11/T48S/R27E S19,20,21,22,23,26,27,28,29, 30/T47S/R28E District staff has reviewed the information submitted in your letter of July 28, 2011, for construction of 5- foot wide paved shoulders on both sides of Immokalee Road (County Road 846) from Shady Hollow Boulevard to Station 562+48, including replacement of the existing guardrail at Bridge # 030160, construction of new guardrail at existing box culvert (Station No. 94+78) and at existing 30-inch Reinforced Concrete Pipe (RCP) (Station No. 409+89). See Exhibit 1.0. The proposed project is exempt from the requirement to obtain an Environmental Resource Permit, pursuant to Rule 40E-4.051, Florida Administrative Code(FAC). Based on that information, District staff has determined that the proposed activities are in compliance with the original provisions of FAC Rule 40E-4.054.Therefore, these changes have been recorded in our files. If you have any questions concerning this matter, please contact this office. Since -I Daniel F. aters, P.E. Section Leader Collier County Service Center DW/cq c: Collier County Transportation JULIO ORDONEZ RAV{ 08018(22011 DISTRICT HEADQUARTERS: 3301 Gun Club Road,P.O.Box 24680,West Palm Beach,FL 33416-4680•(561)686-8800•800432-2045 Packet Page-912- 2/12/2013 11 .D. dook NOTICE OF RIGHTS As required by Sections 120.569(1), and 120.60(3), Fla. Stat.,following is notice of the opportunities which may be available for administrative hearing or judicial review when the substantial interests of a party are determined by an agency. Please note that this Notice of Rights is not intended to provide legal advice. Not all the legal proceedings detailed below may be an applicable or appropriate remedy. You may wish to consult an attorney regarding your legal rights. RIGHT TO REQUEST ADMINISTRATIVE HEARING A person whose substantial interests are or may be affected by the South Florida Water Management District's (SFWMD or District) action has the right to request an administrative hearing on that action pursuant to Sections 120.569 and 120.57, Fla. Stat. Persons seeking a hearing on a District decision which does or may determine their substantial interests shall file a petition for hearing with the District Clerk within 21 days of receipt of written notice of the decision, unless one of the following shorter time periods apply: 1) within 14 days of the notice of consolidated intent to grant or deny concurrently reviewed applications for environmental resource permits and use of sovereign submerged lands pursuant to Section 373.427, Fla. Stat.; or 2) within 14 days of service of an Administrative Order pursuant to Subsection 373.119(1), Fla. Stat. "Receipt of written notice of agency decision" means receipt of either written notice through mail, or electronic mail, or posting that the District has or intends to take final agency action, or publication of notice that the District has or intends to take final agency action, Any person who receives written notice of a SFWMD decision and fails to file a written request for hearing within the timeframe described above waives the right to request a hearing on that decision. Filing Instructions The Petition must be filed with the Office of the District Clerk of the SFWMD. Filings with the District Clerk may be made by mail, hand-delivery or facsimile. Filings by e-mail will not be accepted. Any person wishing to receive a clerked copy with the date and time stamped must provide an additional copy. A petition for administrative hearing is deemed filed upon receipt during normal business hours by the District Clerk at SFWMD headquarters in West Palm Beach, Florida, Any document received by the office of the SFWMD Clerk after 5:00 p.m. shall be filed as of 8:00 a.m. on the next regular business day. Additional filing instructions are as follows: • Filings by mail must be addressed to the Office of the SFWMD Clerk, P.O. Box 24680,West Palm Beach, Florida 33416. • Filings by hand-delivery must be delivered to the Office of the SFWMD Clerk. Delivery of a petition to the SFWMD's security desk does not constitute filing. To ensure proper filing, it will be necessary to request the SFWMD's security officer to contact the Clerk's office. An employee of the SFWMD's Clerk's office will receive and file the petition. • Filings by facsimile must be transmitted to the SFWMD Clerk's Office at(561) 682-6010. Pursuant to Subsections 28-106.104(7), (8) and (9), Fla. Admin. Code, a party who files a document by facsimile represents that the original physically signed document will be retained by that party for the duration of that proceeding and of any subsequent appeal or subsequent proceeding in that cause. Any party who elects to file any document by facsimile shall be responsible for any delay, disruption, or interruption of the electronic signals and accepts the full risk that the document may not be properly filed with the clerk as a result. The filing date for a document filed by facsimile shall be the date the SFWMD Clerk receives the complete document. Rev.07/01/2009 1 Packet Page-913- 2/12/2013 11 .D.' Initiation of an Administrative Hearing Pursuant to Rules 28-106.201 and 28-106.301, Fla. Admin. Code, initiation of an administrative hearing shall be made by written petition to the SFWMD in legible form and on 8 and 1/2 by 11 inch white paper. All petitions shall contain: 1. Identification of the action being contested, including the permit number, application number, District file number or any other SFWMD identification number,if known. 2. The name, address and telephone number of the petitioner and petitioner's representative,if any. 3. An explanation of how the petitioner's substantial interests will be affected by the agency determination. 4. A statement of when and how the petitioner received notice of the SFWMD's decision. 5. A statement of all disputed issues of material fact. If there are none,the petition must so indicate. 6. A concise statement of the ultimate facts alleged, including the specific facts the petitioner contends warrant reversal or modification of the SFWMD's proposed action. 7. A statement of the specific rules or statutes the petitioner contends require reversal or modification of the SFWMD's proposed action. 8. If disputed issues of material fact exist, the statement must also include an explanation of how the alleged facts relate to the specific rules or statutes. 9. A statement of the relief sought by the petitioner, stating precisely the action the petitioner wishes the SFWMD to take with respect to the SFWMD's proposed action. A person may file a request for an extension of time for filing a petition. The SFWMD may,for good cause, grant the request. Requests for extension of time must be filed with the SFWMD prior to the deadline for filing a petition for hearing. Such requests for extension shall contain a certificate that the moving party has consulted with all other parties concerning the extension and that the SFWMD and any other parties agree to or oppose the extension.A timely request for extension of time shall toll the running of the time period for filing a petition until the request is acted upon. If the District takes action with substantially different impacts on water resources from the notice of intended agency decision, the persons who may be substantially affected shall have an additional point of entry pursuant to Rule 28-106.111, Fla.Admin:Code, unless otherwise provided by law. Mediation The procedures for pursuing mediation are set forth in Section 120.573, Fla. Stat., and Rules 28-106.111 and 28-106.401-.405, Fla. Admin. Code. The SFWMD is not proposing mediation for this agency action under Section 120.573, Fla. Stat.,at this time. RIGHT TO SEEK JUDICIAL REVIEW Pursuant to Sections 120.60(3)and 120.68,Fla.Stat.,a party who is adversely affected by final SFWMD action may seek judicial review of the SFWMD's final decision by filing a notice of appeal pursuant to Florida Rule of Appellate Procedure 9.110 in the Fourth District Court of Appeal or in the appellate district where a party resides and filing a second copy of the notice with the SFWMD Clerk within 30 days of rendering of the final SFWMD action. Rev,0710112009 2 Packet Page-914- 2/12/2013 11 .D. EXHIBIT L: STANDARD DETAILS Supporting documents found at: http://bid.colliergov.net/bid/ ANitt 82 12-5948R Immokalee Rd Paved Shoulders Packet Page-915- 2/12/2013 11 .D. EXHIBIT M: PLANS AND SPECIFICATIONS Supporting documents found at: http://bid.colliergov.net/bid/ 83 12-5948R Immokalee Rd Paved Shoulders Packet Page -916- 2/12/2013 11 .D. OD N. ti O Oero£0# a9IIIHa ao iSY3 rot f mr. 'aATa A0TI011 JaVHS NO2fd SSAM3A02IdM moans a3AVd (sire iro) avon aa'IYxoxu rrO2/L2/0 SNYM %OOI O ! 1 Z � i1r / �� €=Na ��° ° c o !,- 1141 k i f1i 1 a ,g�lsli -� s a x Q c0 le w pr ix L O a 41 indi Mil Y 4 ;I --3..1== 4 I U O / O n 0 Es Ff a Fd F w ii z �� Can w� 3 Grl COO W cz,0 m a �0°--0 W ' a� Zv' CD Z 0 0 5.e 0 4 _E, cn w o 1 i 1 1 i.1 TEEL 11111111 U w u ��, ( o a II I � �A °W o _ I o IT 0 Q a A w 0 o K INIM 68 ® 0 ME8 W. 0.'i W '4C i O o-0 00 -)o 0 cc a1- i 0 w h j1 3 !JIi6 a .:411-! t5 ag!gi c 8 E2$5 Yoq nog be AE N.SAJ.6,U9i.'CI+s C.VI:J a¢HS'.C.M.M+C 3 nYAC 1:31.S IN 33T010I\TI4 J, %•••MW31]S]M ....R1...I.C...Cie......u)uanen..mn+rn Packet Page-917- / . 2/12/2013 11 .D. - N ti O eea o .-.PCB wb�b ya!,Repf n.1 I < i O O (Q :9-59tt.0€€t 'oai9S'sya' Qtlti e 96` xe a a O Pi: 01 111 eR vg! 1" CC qqq � � I U 1 ON it , �x i OP -1-3FR :C S `i.1 5 o �� re t a co I !! 1 fl 41E1 lAg 0 e Isla i ill !ill i 111, OA 4.li.li.p i , .1.: ! 11. 1 ' 0 ailliViill 1 W4E01114191 1 WI @ 0,111HEI. T� �1_O Ili-1 1 7s g r ig a nx eo3�9 I�dA hl41Q IRFC e C aSb6�� d� 9a�4:�C � � 1'4. <1d a aig s 111 a is :i. ti, WI i $t b i s 1: W 0! �i5 I i;1 �� i_ A t, Li, i it Roy. g v.,,t isx a I§ 1 / Ilib$ i ia wetii 1 a ;,5 d y F is i ,„t, , l�a d,8§ .- .. ! 11 giif it s 7� I: i 8 :`1 i 1,04 d liar iii isi 1, : at s y 4F H011 �' {fib �j � �� '< �'Y : 5� NI ill 14%�in g tz. � + b ba t Y p g I II g r a gaat s a ar ib 0 e ii„p g” a I ME. eyyN e`gli §b b$ i 1� 1 r . a t z1 a all. 4 al a 5i> z Y g 'V 4-'1 gk-' ors d Q 2 111 I 11” Ig 'Y{ i$i i; I eg�i 'gio li h < rt " � zg �1 gii � ; i f sag 41 ' ' _W.iA N i/X-, 8 n rS.:e 4Ye o : w n n. pp 1e C b NI 1 elsa �� eg y r Its 1S=i�1 if h gi$e 4, 1, ala eb5 t i y ' tl gl� 5ii Y I bad g deli 4' 11'4%"410 4 it g i81 i! ix-a 55 �y q I. d = i g-b 8IL $. 9 tl1 ill i F '1114 b II 1 4a,Z4vr i 1 Pie p? ip 1 it g § 6t1 el lq i o � g i ;, iii iY i E 4€ i t R''t a d`6 1_ " g yy}y777 7 re'ag g t p 1 i. 'f ....: ::w,v:-o..ms.wsc n.war+.�:a u.a m m+a..niiu:..a+wnv:iab.• .b l..+.w�.-..r.:<;..�.nS4 AAOQ Packet Page -918- 2/12/2013 11 .D.- T '.,t4R 1 CO c4 ti O 0 T nW a T 8 < y 8s m r m d z C!? W ♦ W�cn1 SS : q i O C TIRE F' < W i 1� a 6 .0 .V < F�1 � ge 7.,,--:-..... 2 (I: g i 1 X cl . co ° 1r <Y�u V g ' i J po 3 i II :Ili = I i N~ a� U ^ O I 1W NA !!P 1 1!1111$ 1 .b 0 w I W f v, � 9 n_ o I. I i 1 ir,...,,,,. F°z w —8 —41111 t 2 IU I > xU.-, el migs II i I tN- 80.1°. 8 „l' Iti § - r Ro ° z - uh a ao�95°s` illx a . '1.I it n ill; ams p: p@< S. • n U:nvd k C 8a �<� 111: r 0 8`> � - -a 8 as I p ! , I n v•' Z n \ WO • ,2 I - blip I r. Ai _ m f g5 X61 1 < i 1 I I g W I W U 1- a,W a I I ` .j a g E C I u s I ' I . II i� j C. I ° y — - - - I a I 'y 1 , a x i ovS ■ ,may U 6< S 4 I o N1 1 1 I Packet Page-919- 4 .. 2/12/2013 11 .D.- • N N O m r r ` • I1tiy p CEO = ` g a �" {'. '411 t 44 i 111. 1 r Q 0 4 -.. h2 . ," $ ' a 3 o II $ a g 16▪ 94 I r V d' yu j ' `n °'3AYd ' Q{3 I I �O .0 Q. �rn is" "=c,,� - x acts I,. � �� W < D , > 1 ' i i41 Ir s 'fi U 61 ate. ',. i I " ;i 1 i\\ r6 .. t U.. 2a pft .figg- 1 (G�} n p g' AT.'W .�2 G F T. Yt p+• a. a pX S �=0 0 0 u a: a r r' "x ,fit�` '4 i�`— z ,4' x.9 n !! 0 r1 iF B U34Yd .-.� Oyey:; p q ( U h ,.. 7591 _ ] 1 as�, yy x I J trio kk .. 0 . `' �I!'1 a i ...oil.- +a ms'µ.. rc d m F, > fao !: I ill to g r i' 9t Pa I � h ii w E �4l." i e, cc Itfie.'-'''," ,....,,,,,A-....v ,,,,i.• Q --ri—,—,1,-7—, 1,.,niii lEllii ` • ' $ s 11 t ' Ft N ,. z° aKSz 9, p ,V 1 1 y' o Id y `� 0 W d t., ri'''.' l'' t, ,,' -'‘'.'.' ,I mmr'�,.....n.w...wr. ....n.m..s,...r.,....�.,'. I Packet Page-920- 2/12/2013 11 .D... ,! co 0 tn! 6 b N •e Ali..., u l= T /,'.!,,' r 1 Q. r ark rl �na Jr S I Z co F ri?3-I 1 co ,via . e � I , F V 111, )4,4,,' x.'' ..7V I' U,i�Vd n .D�c ��.il i s . t a >.- '^I �u t -Fi t Ai om ( ',:it.: g ;d �� ffl jl�i l i11 � z �� g N m ,yin r, + M °2_:—.4 ti `r • �` `l d o P s f op F �"I -aZ t ,3. , o :,-,i, tX-t6.;:l.:a 1 xE I , � mss 51,°a @Ili 1 x:✓ 1.I )11'' tom. i s� v$o` aaK� st ita d 1 `§� X 1115 . '-' , :,.c' :11 1'AL: 1# I rys ,„. I `2 Baal§ w ,',i':,..4''-'1 A tw� 1 „. I ��a — os p I 6 x � e ii 8 �� A- ,„ V II ''lit 1t1 s '` I- iWn I 54 i i. 3 . vl i a t I, a a _ �Y w i '.� 561 �� 'rt' ,5� t �I '4.''” �'w �Y� �- -'cad 3 Rs ,I rry.i qE 1wt/cLt-e+rsini U tIOmMno?-a+wd�:Aurrs as a tOfl4I sw\•ws €t tt I5��aw AVMQ OM°°i��-a\a t.. •,•�n=w�•i1�..� � Packet Page-921-_.__ 2/12/2013 11 .D.imi , 0o N ti 0 -1- : i e O 41 N O CO , NI 1: ila . c: 417; :1 - O w o d o'y ` f -. "= e =a e�w y li v CO 113 v ' d � Q a ti dYi aa -,'z-ES W Q CL Ill' 1 _ m ;;;5°4 ° � da gill =S 3 .t 6* ,g .O dw v-,y§'" zz dY i ° e e2 W" W a- o ,.g- g'W w2 2 " ii ^ g v; "� god AW < ,IV ow 'Ink `6c ,_ Y{ j ° RtImg CI m Fri 4 W d lk'∎: a mia�y t. 1, . 1 ; r4; z ., Rd 1. '1I VI �ll lir i <s; (:):1 2,2 P S8 ■ W 1 I II if 1 I 1 Nd 0021 t O7IJl/9-6.,,,3 e00S)Cre,\eeo1.0 0 0S\,U?V0 ab.31Y00 Flel:ud\•+01,.vnur,5!Os-"oad AYN0YOa\5091'6".,\&..5t,w$05 dt.e,y\:o I Packet Page-922- 2/12/2013 11 .D. a0QI ffl 'IVAIVO 2TO,LV9 ,1O ,LSVa S'IIAI { 0,1. 'aA•IH AOTIOH AQVHS NIO2O S,LAI aA02IdW1 ,—I 2I2Q'IROHS Q!AVd (91>9 '2I'O) (WWI Aa'IV}IOWWI TTOZ/LZ/50 — SINIV'Id %OOT Iii }.--1 b nI w vl-iFW C iy{ 6 }p Pil 3 c°P� „I e"S <_,,,, __;,_.;,...i i kifir" •-=.• .��♦�� g aagR R_� €~q0� o X11 WYy ol°5 < 7733 <pO11rj NNW* W �20 vs ae,mt li ''i wo qi silE'" g.,, 8 d� a!$ liri Z 0 W 7- _...J s 'f: 1 O p QO a0 ' M -J U1 ZI= g g: U d Oa @ F fYWd Owl` fxwc^O z in--, 1-X + OX + W z0c\I <wCD Iwo 3 & CID g W �a`o z0`n c0in W ' LOQ wEI zr- O wQ� mmcn wmcn O ti) ~' w • c W�-IAv, o / _ ®® 7 w oa n. u d 3 c`• rj p5 Ca F � :� i it ¢ 4 u E w M aw. r p i pk9 5 • H w 0 0 } 3 ...,,o o,, o I I. < e 11, v x n ie i a a e of Q A h 2 !"11'1" I 1I l Y Gz] 0.4 o �li .) � I III. : V v 'CO s ze a :rSL �1@ n E Q cn J ri; :I.I I oiii.:t— 91inAs6Ad-a.ii„.“..iW a m ' NM 4 d d d E4 <: � Ooo z Q' W Q1= + CD x N � -7 I— 0 —; Z �. C1 acx W b i s-m?� m g b i 8 Wg 8» N <N<0 W<2jY <0 pp W =`z N v N H pc) i 1 8 • � ,0 5 d W * O 2 W12 §°1a. o�p 4ti�C w W <WtN � z.� W a i < N6aWO9 S lN <a d8 B WOK O2 9 W.a • N W ZNWJW. H m�2 a 03 ill L_ Bg, RW WWa @ <N. O U gS UUU g ag S W >O NN2C >. O d d ti mod, ?- N6§OiN= m -i y -� 2 NYO =<22Z�2t- t 'i-:5' zp ~ I"1.4 d2 W F,NN G p \ p W no1�� <KU<COi 1 .-vi Z.15::::".1.1::_1.C:5.96'13 vx,s )voi�,,,N..>R .n,c r. r5 , ;sw,_..,_ .3c•� .i.:.)r0E'd A'WAVIO :uoa.1,.59.0\5,...,5,3 un.4%;...:...._.., Packet Page -923- 0 2/12/2013 11 .D. O A f OR 2 F.: F H g £ 6 ..88 - § f; ry. ? �- �°+�---&xw R_nk,. °' mo s 6 % ttttaaff 'p ZZZZ YY y>> T>>TT Yy `}yy { x q ( m D r�ULLJa ntio iqN WCxguI YIU�W:I�i <<< 'uS IliuJ It z 5 4U I I Eg ti �0 go. 0 Oo oki 0 4 m em fl 4 11 `1 !! °! sm - e g 11p t ;1 m 5'1,4 5 . o. m li m s o R gi Pi_ p ^m o 8 o w _ R . m w cg.�i." o$ Dm°� 2 °oD p' ail a- °- s !g, 5 Qty a,',;gsi ::: ,1 o D 20i:1141 i! ii1 .8 . 1 -_� rigg El ^ 191 igE lE g m1!o a P. 1 i li �yu. Jg xx [' 2: E� °> �y '�°o ° of �'' o8m" o d ;AAA a< K0.a0u °M F.�gd, ..7, #,InW,GF; 1$ NE.P �k .Y� DOV� 8Ri5 iC/ 7 y �� a � d �� D2 5� 8 �r� � � gga gal w6 m-v`ii''hi:1:10 1g11 7g°g7ccSF a°/s:'� 11 gill qVa„c � R 9i�6�:� �i Ee�j'�fu��5.8��m.Y �Z nr c°,5z <� °a � 8 e: zop mev §'m z .o¢ !i a g o u° < 8i m R� k 14 1Zo 811 ile �V] 3p <<7f �' 5 a.. .`yE�w�w�st._ cs m t �DA$>$ �i � gg ��o �” a wBB pg v o m ° m OW '� p 3 a t 8 '^F 2 55ii °:�+$ W --";;',7-"12k! a as� ebb �� •��d� 8 r4 - ;a ' aa2 � : ::i101� � ' i T.E.i°Ted$ i i zs.oveJ1g d� To 7, b ? © 444<44444 < 1~r‹ .i 4 E-.0 F E o,`4 oY ~�4° `' �o7 nD O7 nmmr o-D mbr pmm� o 'i• a vi 0 '< 5 m o W o � 8 W b�j b b b° x Q 1 M $ ; Eidd d a? 0 pM<1Jx my i �Jp p a•U O . Z ,' U G o Via,g !I a ILI Jm CC�1l �ZZ F'=1 tllU � 20 Wa � aW �m� rc= FY S6 ptl <p p��.lpl° 60.T OZ\UN xo #� ZW S �O m O` O",-3 o NN rl :',I °U11° . Ed ah NF °< 0 b $ Ihm I H$ iNl' a o o id o ! m a��D�{ czii Ri z� ! = wl�i.i� � w� j�< � a¢ � �� a � g 8"9z<`o 0 �� m a ��L�i�`x �` °°IFi eizw—`cxS m °� ��`�° qB^�UU z Y= N K EE33 NE-�0 D � O� � <F c]i K p m�W a <U NN3 h ny � <® c.�q g�1+ � Zp �D6p0 �k� M 2;9R t,u gE cz 5 o U'i 6o ya i. z �� e56R F � 7 ; sm m z a o x w W K�K 11,,55 s �W JoJ F � qy� p o O p 3 .pTI.� gyp} Sari �F< � II U WU � � y C< <=W 1�JNa�a � N� �<Fgn �m �Dpy�{�mgOF � n!°+ ��W� pO�F � °5 IOm'S ggO II 21 2 i 1,F` •1 >N UUN 1 m< :oc!pi�m0 o;1W CF E h.tl iZ°U' gSO1 Wim2 : H; g=N� ;6o < gz o% ` $ i'al gC !€l 5f1 = Nib U&y41 vE RFF D g � ?l"u v m. N§ ° N �FCzi 82 z " g<` yc ° o �Wa vi o uw uaoqq F �� oSma �ma amW�m�z a� Rag Eg°i7. G°2 - - 82 7L i g wi!j� uN 0 °p� O a 8< �'5m gii mU o si l si q W ap m E3 d g z& ° o r� gRd- OYo< E2�ZO y ''',:,z <W W o flU o w xza m� moNa Iris � o � a�y� � ��°o� m c°i� ��m a.�0<'h Q��si lii! oz < ;35 H m O C o3 aN :g vEr,-. 1' S"i � ]o°m � >N<3� �{ ° q(• 4 W h N *,°z Nn.2 g 51' ;3� sRg ; ;°2U O�< ,g-a Ei: =< <¢ <EOW < g 4K < Y pP WW3 Z cc Oa ° g 3 JO U(7 SO Koa =3i ;W l wpp Fj ouf �rc§ =i° 32 49 =F� 3 g g =� P x RI wg _r DWe i oop E.0.m.mp.D.0w118075 og 7 o2 ti i' N zS -Ad m< ci= 1 1 LN <° '< g?zg °� Wei dl g Yo goo z m+ � , i *� mpm rioa.g 488 vi ' 6d r 6QR aoo3 rc N .°, c°a .o. °8�8« 8 o N9 �w7 o°'i e3 8+°�n OQm'� m n a Ea< a u rcmOd w $� bF WQ �w S g `3F aPt. - ;,°•o 481P1° V e' ' Mg`<":6 1° o- 50 ue` .' ^_ <&o 4 N=°= g mze .8a 4 O. KS JJ K F u�4 n._ o�.'j�C � � N m� �FS �jNJ..N a'� J GU S wp .,ER OmN U pP NI ,3,2 N N S2 c=D El O Zo .W,Wg< U c.c2a gC oN RB NN <422l mfo a g< 0 7? ryY1 n� N N N wNf4� FWG �D LL� .ONQ<s I�m6Oip OWP0 7 W L,- Y HF U°¢ �z OF no oa A•o1 r N N .z K a< < ., o 8 T`r Z � WN 4� aN 2C_JO A O10 O 0 m p Y <m ¢¢LL 'O <S G< DU U O gS7 3a > 1 ag; S Ow Ei rjnf .f° .1.1 h 4 Om U SO2N 0 2 4 :16iLL W =OW=a' O� W Dr F �Q°x �Z� NN NN N0 N N N ^� F..Z SSW Gl6r � m <¢¢ FKFK 1 SZ3 OW Ni <WN WWU°I ;UN Nh0 a0,! �O_< ';`44;4 86. Wi 2W� F52 ><- a MD w 3 F ao =ZrZ g�z eea !y¢��Y p y<N N F4H1Wm <NH ppp ~ OHO SNW mpw a< Ip d VOWS �a�� U OF 30".6'8 F41• �¢�¢ �.:,,i Z <S< U-.> > KgK,U, Fm gw� 41'1E11 S Wxry2a 6 _ �UKNU Y1 V)a0 Ra • 7020 Di U 4�U bU D Wy O N�i FEW U 6� N < . zLL " o= F `O vg Y >y W z 3F ZO uP0 5 xN U W< =pJpN NZWZ LLWp F-¢< ZyW� j UDU F S DU DO �+WO §04,6 U��113 ; �R F= ZaW W 3 < � >> ¢ p �.1 WYp � qh l= m 6- <6� °O Y<LL Ka F gp= W ,1 j i l 6 I m< ON O= U c` aZ ° �N m 86� Wa z � J; oxN 63E � a� � � � z° 'da50— �� o�W ° o ,imx F� rnmo a 1 zW Woo � �� W } 'm"mwp <$m wy-y�� oaF �FrcH o :::::ae'-i 6w ZUaW w K6 z < N6 06 <6 O Z x 6{j =p< DD ^ ti,4„�.o 8.Z6 .<!^ W o o°- iF„o ,a W �j caix Ux z°-x : I” F ° N.. wz :: :'.1:D::pz =r �mz o vid was t o` gS ,1 4w,♦ og �i u o�^ --:: mx < xwa:� v_ KQ 3 $2F � N Z7 2W 000-I-- N y.... ig,U j ZTi 2Z OI ..j� q, zp��pFy ■p NW D I dOUOWN¢< WO NY .1 l FD s NV� U.. >> <a C < ~S1� 8zq SU-O 1; • Wr0 2° OWZVF.h =< _WLL ¢j-. N2d 7U 4.i W= <OK .6 <YLLp ZSFU e 2W W� <_< ` FO ((U; �ySO OyZ WiPr �NIZ/1 �< p2¢W S K y=yJ ZNZ��O OG��aG �ga N UV Jm F<U mC 4a0 <Wr WWPU `Z°° 41~/1 0 gCLL <> U <g N< gigs=rc� U zz W i U� Uyj W OF <N �° p � `DW O= p22Z ya F �R yyy1n.,,,�CpZZ ZZ == D DZZDF ZZS K''N < �JW$ .I 79 Z1 CF g-p,:lf- _ : §F1 §pya1 U WVUp U,3 S 4$J ? SI 1 FN .N< F , FwU< E< `°5 4F2,,s (fEa1 ®,,...y° N YFS �(OlO,,,ll N W41U Oa��Nt 2yy° qUq O � ¢N¢� U N Xm 2 <m N� N �O�J+ 6�i�10 ,,_,,, NW <„,.q la <J L.,g2Vp 9g'FUO vZF W U �N WW <OU Wy WJJ I°J W°U 6 oa< W � � zL �� SSN C^GG C i w Lsi°< p oo Nw6 @E wF ,t i jt.ie ::-.2%1:-4 i�S c-( ,,,.c ..icz°.,-? 1;04 �7 N�nmp3US Y4, rt,2R 6a ^CO.rc Nm� N 1.�iNU . a LL6. -e.... ........ o o . . . ,• .. ill .. •O.. . w.. m...0a....,n �,. ..�, t d®®4 Packet Page -924- . • 2/12/2013 11 .D. pi W a..• o 0 1 u) 7/'''' .------i -.... i JYm IX p v+mvw w a • W Z O [WA V W Q<< < 3 i" N as cS F0w .7 m 1 I-5iom W ° o.. ZWI rn W07i r� 0 ' �F O 0 i T-- p H • 0 o d I.W I A o* x < • U�ok' 0 a. W°w E. c).. Z �w a u • „.ni� 1-: .a =*.`o a W .: 'b C lN'-\, °z 5c- 0 Q LW.1 J Y W p Ja=U U' 9W - .. 1 Pi�∎� N9W W E'� • W° ii =U UN N •.1 QU0 z o ? IA �\\1 JJ U W 41 pa d °I/i < <w�.1 v !• .N N ,,,, 0 iii i L" 1�\ °W 'llEi I yy p W o &- • < r P' 1 1m g!ni m• u< nv << IIi go g1!!19^ W EE a AZO 0 f -ffO� E.EE �_ 49 o �d� � one Ll I� HI pitH j0:Vl omwc5 i In mZ m¢==w E Ul i d RP 3F NV oUs 1 C - v S ON N H� < ' <m WW j 0- pU fW �O wt.,' W0 F O w � \4_! 30 Ti W W W OU m ¢= ~N J>p i m o C O ILW a� 11p3 wNr-¢ 8 <— v, ZZ O'o g u.- 0-W <!1-. °*W F F cP6i n > i za �n xF 1w �� co N 5 . — <Z UZ 1Z o 1m , Fps '2lQ1HS o 0 r cI ° o w n o ° Z w ° � , �, mAVd I :i6-w-h Nzw �Z< P° N < A U •p Z<< X-0 X x w XXW Li mU K W li J U V-N W K< W N W w W W°VI J.-. ° NIA 0'. w J Ii -wJOH N1 L9 h1= *o--g hZZ x in"7" QNI0 -,J /III • O2 0 Oho° v! u. >.>... i- b s w 4-<, T 10 z < : wo�) c cC 3 .. p !V ci+�--- ; r p 3 I:.. 11 Ind w04 qpq N . r d a 1 O 14 1 I ° r < ° J w I 6 IN w I1X < 13 1 0 \ �R A j • w 1 ,. Z w: : W a 11 1 . W v .',i in . w I —. 'W ® X II I W 'X 6 • L---r_ Z :.L. I w ,.-„..c C4 18 % N• in O� Z 03NVd �,' Ey a 11 r.c N O \ ' Q > J QQQ t-1( ,• i in 4 rm N= gaol 0 II I N Z N .-. Z N i O W . O Q N <_ oU m• V ' < J N G ~ a ! _ u.re ! • W 0 C� r.--1 o I I < F�1 E g a ✓ ^J= H J w E+ Z 0 \l o N2 Fi < � W ri a W i � 1 i • X� 1! !:� W a, ' ® iii II d u \ w o < W• N to 0 0� W X fl i 1„ W F x Yi it... Qp> W X 11Y > E V 1 N�''2 W 6,1 • s is3 wv+o cz a zloz/CI/u-6MCCS aolts>tonrvl\I!oa0o..e 006d\I — —----.-..n ,:'--•"'°10\st03r00d AvMOV00\woal u6!so0\6u!ia+W6u3 u','°-'dcuo-'1\'9,1I44 4114 Packet Page-925- • 2/1 2/201 3 1 1 .D. �w off'• 0.iii4 .4tol yp b9 g � aZ„�9 YO 3I. OC N On i ,f f'. I fin. xr N $ g O W 6 OZ S V 1 N Q �w , o . 9�9 „ N� 'ao�HS ' z w< o` 0 0 8°- . ? CI3AVd o v'o ?., m r z 6 v c� _, °•2 W a < I 1WAd 4 _�- �w 2'..1-%- =n4 v ° ° 1WAd ---� d p •��< n 13S.p Z u ' r I - r0 �s:' �r (( a�� fir-• DE � i� tp 3 H ^ hM 4e urg i :. ion n o, o mom° L o�z '1 Z A E-■ o ca = L o u ¢ a u w c --- z w of w _ Q?n �- 17'''->j r J Yr E-I� o ce re `tom � iz ' �o Bpi`` � — = C-) • ° �� , z.-,I � I u� � z Nr�.¢ A O ce • M1 w n .I f Q�� 5�: Q J z i= h C CO J : 4 `¢ j ` a .. r) a Lfl ,,-.a v '%/y i j m ""fi; •A �+ ! /! Q'■ a `�#,.. °�a � � ,',,-..',,c1,5'.-,/ � �, .�, '� ao 03AVd 1 A "' i ' . z , Li d . : A + nJ1WAd v r,__/ d 7 r x z v t �SIW , I M "' �° w0 j dJ3 ' NEVI m w F a3 w ,,,y. Q c i U a »L j Q W yZ �q� pP _ t. O � 'c, Z 1-v' Nz° fx Osov :It., r to vete" Q I. w s1i s o z , W 9 y, 5; If.L +J Q" J: � QQ w� W 9O9 Y+O 2,1 Fi qq Q� QO ¢ '✓ N U� '-�N y It 7 C2 fir. 6. 5 F O R g 4— 111))) 4' "` �� - ? rn m w ow yK 4� ''',4',4:,,,,' Y 2n r �. V', x£,e .; e 11 izi • A _gill y `vre .,,. y, z a ' � $ ' ," s w d x � -� J W I I a w owz, ili I z a a > I1 I °mom r c�ct: 'a r, F f.., "� --d.--. .z} ;;f 'amHS a I . � ' vi I w J s / 43AVd 1 -I L_ d v a ¢ / iii m' r4 1 --I , Q U zur ta' a �I. ra, Ocna, O 4 ) �` fJl , s: T < N KNJ Z � d6 H (O k�,x� � � la � I Q�UwJ g �� Q $ _,7 zc0i wa I w 10 -I I 3 p{ %k. Ow�v= a i C Tilt-41?' : '' '' ' ' '.� ic.;., •Y.n�ay....\ w+wa\�u�,.s m mv+on.n�wvvny..rv\sur... i .-a•w,..wo��+,�,.\o € Packet Page-926- 2/12/2013 11 .D. m ..] y LL, G FZ in I m v N l Q w+" N V _i Z ...is-g _ _ I U O d Oz i ; I 4 6 W° aUFS I W cl COAYd Oo �O I m5m W W U g WW W ! O c"� , §i }pi=0 W 9i9 p_a ce ow °I 1,2I W F Nz ° i _°5Uo•33e Pi h Z V W C { 3 � K 1 g QK� I 12 :In.....!,..!.:iiiiii . re W E. ap w ? 43AVd 135 ya•civ,.4 Q,ai • in vTi <- _ i 1 "' O 6 w> •rJ X F CO I N W A 0„ ., in �z �i o a. U d w I ~W N O J ° O i W� I z o xa °Q - Z W . 10 I W O I Zz F_ in WY°O �g�° i c 4 azz = ao on N / 'm i vi z o c I I ?I LLL'°W °W° m tw° w WPW ' 7 O 3 w �0 a�p �� + Eo�°O qqCO 0 SillikV) co �j l O K C sm N a aoNWO� �K a � � °z ce Luccuja R 1 i'i'l _ ee in 1 U p K <W i 0 / w a .a / Y X�+ 41 d : ° igg • m W< III 5 cc • i w m o�i it ° 3 llI e 3 R w 61 o o-�o X< °a I I w o Ei r UFO O0 B W N> a9 Iw1 10 < 10 U ym ,-N p Io az U°U g O °wz I ° ',lc' I I W Ur $ I �. KY /S f1l 7t(7Z/f tl 11 -6'P"''NI NCIHCNf1WY11\sPO,an F .1,4\l A,7- -• uEisap 6uuaam6u uoi o„otlsuo, t<~ Packet Page -927- 2/12/2013 11 .D. i C° � > la X :5g X g < ^ W <I NC< W N iI! °z_ i aj ' °ySZ� Z�z� ° 4/,1 R.K 1 6 K o°ZZ oo= <1- jWLIW„O . .- .Z g 'aQ1HS I'�§ gg Ko gr mm6�al W z ,�w lu NZ 4 03AVd S lq Ca�ttX _°< sW C'LL W1 A'w zd c Zz=w 0 N Rh 1�. VV N a a. F �W 0O Fj W W �zmO~ w' 05 /yJ r. WU v !- H WX O< j0 Z wto ON<_ N ,E, W z > o. Y = J /w , N .0 Km ,-Fa li PJIt (g gz OY <2 ill mU 'V JU C•71 2 `o N H° �< bo<p_ 7Z �p Fn •"�02 00n rz, F a)W J~ KO .< Q0 *z,;6"-ONz g 00 <1�� e6ai/!l Ir 6-1.� 1: ,' E- -g • 1-,•1 <z gO Y N W J< <O ii6i/t°■ ENO f,� U ao2 a+o y�� Ws� _mommF ��.: d W „ =rN •F. x3 l i "', 0 N 17 a[�% na° G•5255 ,1 0z NO Qi -10 - C4 re 82342 i ' O Y i 111\ 1 I Q wRQi l ;I W -. UU J � �4i a ii Q = Q RI N <WW r NZe-141. -7-r N tel '- d i F ni J O 11 ' 11 <3 F s x z II ,I ` o H _ I 'N E.4 ,, < 6 r 1 �� m Q 0 ° , I / m q: a ills 521 WNO z CZ. vm 1 . . 0 C �: .: W 86-3).4 Z y � ! �. • I 38 r V a Q3/5Vd q I II I ! ■! i r 9 � oboe. 1 N Mpg _1 ��' I, 1 6° o 5 Iac 1 wg e°. 9 1 W Z m iii Id ' K '.W.W a- a . a I m � 'n Q mi 14 rt 19- W�.2 z1Wn W oal�ylt'efl �, N ‘.-,, <'' 1 �o W W 1 NO< N )4.'011140111'.', d Q"'";:-. 41E07: 1. (/ W1.�B w p PI d I' 0t I 4 N �5 O 1 yy�1010 y , .W.1( ��■ � >7l"'N Z W M°I Z: : 'I Ali';^ < + T 3 j , -W 11 .vl —- i--•1 �i O = O O X _ 8 W<W o m 3 N I = z Z a Z 9 <�91 o a ., ° ^ e * �1. IIT, t 3 so:41 o W ,), • 8 * -44. o o N I i i 4 I W H 3?G O = Wa<z ° € Z 0 r•a 22 4y'- •.-- =�z I .N Ua oi� Q ,--1 Y W•-' J 3 y� I LE R4 E K 3 o]O O '-' U y8j N I. i -J 4 Q I) I W I W to 4�N <1 0 o U J °z p l Q m” a o < 3 u m YF �t�pl...I I 1 I ,51.-Cr W I� p I►'y 0 V'l ( I a N'30_ W n l� F �� ,i!,■ ._ m 4'41 :I RI o2 Q'.1 O f „uI I \ ". al <J k a )i W I i W Qi m W o o � N' 1 o re 'HOIHS 1 I 1 X o '� o $ ( �"9 :.� a kpp in 03AVd 1 1 `"" UI d N N <a=//' S I' n r YIN i 9 (� r zzo " YU' f .� p ..i ' 1 a k a. --J 2,-,Cr". a C E W � .i r I a O W @ i N r. WIZ- ! .ja wNa O / :m q? go r1 m .1 e g X N..K 6 Q W T,{I I• N* < W I . • N t,-, H• Ov W O N W W p C n � 1 Y/V SZ'II ZIOZ/CI/lt -6MP'9503 8014SM0WW1\c10la0 op uold\l A134VS Oa 3Th.NAAY1i\l W\cuopoocsiul\5103POad AtMOV021\."1 u6"sa0\6ulKaul6u3 uoliDVotlsuoq\:O 1 Packet Page-928- 2/12/2013 11 .D. .4 m t � r'F ; -,:.,..:':.:...-"-.7".: '...,:r;i..,,,,,,. .,. ,,,.-,- . z°' u of'"` °E ' , .ws W , ,,..P`.''''':•-■-1;"'""7';'Z,.!:.',:i'''Ci;;;t:.1.tit."'.'.i''.''?P'"'<;''''.'"'',. , ''.' ht, ......,,,,,„ -,..-,,,,,,,...1.,.-,,,e4,,iii.i, ,p! ...z.,,,,,,...;c?.. o a s , ;'_ F-' A �� +E ^n 1LVId a i ; $Y oavo ` t b ).'. F Y Y Y; F � : `�t dt_b$1I * ?{ . 1 s�Ydu a aa�5 u63 wi.., I . , � • = am t� ' r r , .-# '31,, 4 i• ,,h ' �S . �r.i-sii'-'-'''*-,,,-',':-.-.-,,,, '- .,.. N, ' .:,: :. ,..ggr,''',6.:\,.".?--,:,-"i.,,4,,•'''--,,,-,-:,',.-i'N-4-;''...' --',,,'" i 4.44., ..;%tiNtItf, . �' _�'4'';'4.1;.-''.:... '-''740,k , ., - :4... ,-1.-4,,w:',",,:'-rt'..!, ;, om . ,,,,�"� ,�Mw"Sn N� , , #fi' ': a ce`+ ,. � k` '':C)1 W 4 ; ± Yk � a# z JY Yr ' e 0 �� 0' _:::;1.,';',, g� r '4,',1:i'')'7-74,- '11-. � ',.i. : a x o' � z e . W o1� a d' "' "d i , a ' ,+ I� ' a 'V, a ` a [=U i` a �I ,` : .� Vi , x� ` a L i .y y � v 1 . + .,:rk,• z u p .e r.k., ; a 7 Fr "3 K1JQ te., y -2 y , e � °E� fit 1 fi �v ,, • 4�I per- x1 .a= -"'s ,h � �< O- tT T . 72, �ii t' s "S a▪ eo` o som 5 �" x' N A sue N"�� ° ..� �� ,• ANN*, :r1 :'�w` ▪ 3 i 4� .�- 3 h�� 7' .mt\:I 7 ww 3� .n� .v,, W D,1 %\'. r my\l inns i/u-s.Kt ev» \v tai tiWt -,,, ,Packet Page 929- 2/12/2013 11 .D. a . pi .w. A�_f-.x'f,..4 '.k A. j '6K.,"f A J * `r I Al / - , iT� [R •.\ u..;: f s' .1 �l 6 •• �v 1f jj33/ I r' :. p3 , , > - I N .t � 4 .. � � _y' wH � rtp w , a `:. s^ .. "mot / -i. • - ,,R w .r 8 I" _c t .. . 'J - 115 I Z-f,,,,t,-,,,,T �'M . Ja +„�/ • I n I "r si I l w A c4 z12 - d .p fi O a <• -or,.-. „-..W „,- ±7 I �� ' . ' . ' . . I ' I o -V a,....::.,:x;.,.-;: x o J � W a ' ( `v c ; ` . ; . IJ I a�. —, � °hy . d I FwAi.` 4 i� \ , .. a 3 '"oy . 2 I'M G Vii. k ! ,1 J O `..2._--' l. ,° v y - a ''Q � 'h ;. I 5 ^ l a `, _lj l I 1: 1 u}5P 5'-'.-1 .� wh'T' d 3$ ', CI) ''g ,.....4; :: .... c.,a, st .L, ,,,,,,,,,f,z_,..,:i...%...3,:.4.:,:.:4,,,rif, ,-, .....,,e','',„...4---, ...,,'.. 1 I 11: 4.'7:''.;..1;.-.7*.z1-"-:;.11,64.:3"61„."°41tH.,_::: c3C°.f '' .�, �,,�s '°�' di p.” r ao„ .-;:-.7:1 �” fig. r H 4' ' p a6c e :!•;., ea. t, • >n h - - y+qqq 0. ji,„ ,.+e xr d ;'+e,s�_H (vim 24 m a 4 c�•: ',',. 17-*:- t r O m o a tl�'p I F, 444 3 Md 1� I; a + m ;.s ` :I; :rte a !, � 45:, .ii," � .'��"' � wa IS .I.:• o 2 ��} 4 ODU�¢Sa " r � 3t` ' ^� � 1.i s �, os� .e' -t311 11�1-. ,---- 'th- I , - '„V :.*:..-- e. _•*- - ' ,,A"...;..-62.1-.' - -, 14-1 i , •'',,, - ';,.-,..,=,:li„--ts.: ,„, ,,L 2c-) ,,r, ,•_:,..„,:. y ,:,-._..:,,• .L. .-1.„.7.,.n...,----.:: ,_ r_v_, 1 ii. .. •, 1•..1•_, :,..-„,,,t,..i,,,,:,. .._ : ,,_,,,,, _._ .,.. .„ .‘,... , .. ,. , „ t:.,..._, _.:.,.,....,.:44: ,,,• ..L. .,_ ,...:..:1,,,...„r.7,4 ->1.,,,.. ,,,, ,.1,,, ,,,,._. _.,_.:, ...::„ -,-_ Air.„,- ,, • c. . , , wet:.,!...„..i... ..61.:4. .. .....:•,,..„4,..,..:.,. , ., E ',,,,,, ,,,, ..$-*--• :r;,,•-,4„,,,,:, i ., g. # ;to n° #'"•' "'• `.a a4. ,, ,�'. . n .. , � , n' { I rat'. Y 3$ I ,. ® ., A, ".•, ,' .. , '- 3'- 1, 1 1 t., '_ S 't� • k"1' � r 1 r ii Vi{µ f r' k ,t+ r . 4 La we c loaf LUL/li/.-1..21 z1 u°K...W.PM0.EMI ll]M w d1IIDn.\lUf\...r.....1\SI°YCS'' 1Ya"°.1�!�6... d rMU^I.:di\'^., Packet Page -930- 2/12/2013 11 .D. r _ rt,''."'''':';`,'.1:', 4; •*,,,,,1 ',,•,-44f*--4.*1°` :, 4,',,,,1 e as `,;,-:‘,4 t xs' �n k t' ..v-,.,„,t,- �. . + ' ' ,,111 a 1,. • ' ». tl,,;8 ', r t ,r- g f 1� = :',3 '',1 °—mac o. )1, 3 u C ,� ..„7 4, x F ^tom } ' T-x.r. � �' ,Nt . d ��.'"--11,,,:c-,457-;:'-, 9i''Y 2 ”. , h`, i * t':\ 1 y a ;, e „ i ;.i z �4'P,, y yp -..�,n¢ , -., ikit,iii,:t',.:fli''''�r , t z i Y S a "(� :ate :1, t ��rw v .�. � '' -.,�•� i�961,44,---,!7.1 "� > � 40.,�r ty a ; ti ,� F ,rte', "'' t"7� ° .,� o z i rr YA. a k , rya I iC a ,ate 0 4Y�t .' F W W t,^Rf1 �"k ■ W =IA Lt' I 1M 7J -N� V ; a ��b 1' � co i '7 � y, }ai ` ' a 1-F o ' $,u� ''�" 4 J "sr;r v ,, �' - `4" �• 'w ..�,, j :-.04-..-6-4'fir O ,,,I,,,,,..-Lesx� 3' "� 3 �q.7 .7 �l ff�J. 3 .I ` r �.. �t ai ,, _ +,fix. � ry "S c.r } �', � � � � 9'� �� srF t'Y� 44 f. i L e0 9 O r a rr3 I w t > >i:; a °� a� �� P� .: �. � � ,�et,s"',,:-„,;•-•::,,c'''''''' .1-..' m E°-m M q7{ ` k.. w, yrr>i„"f , $a, :, a,:.'q,8.', 1 '4 t`'�t+ ,I'. ' ��w._. 'w.” ---1 Vo a'�a chi 4 fy 4sa - L K '? F +. , � ' x � �>x `c 3 "t-;',47,�, "� � a i � �I xe, .+w°�` n ct �� r, O�ry O� �3fi #HI p ''sjel,,:**A"i'lj'Z '-,'''‘K 1 '',‘.. . , 4,..,, E I` k'i�' , . h y r s s fir § n,$t,'' G„ ,%., ,‘,...,, .....,,,,..„...... if) u q ' . '-,''f ' k,,,,IH441A '‘..,g,'' ' 3� �s4 4- z N. 14 � f'. � , c°> ',m °a :ti s.}, �, c �,a:.'�w+.R,` i'�,v Yr> o r r `.'' I ::1,...;.<:;:„; 1 W. G 4 #1,1 .T.',U,'Z''s:''Cri.1';‘It';',L-,,,,44,/, ,:07Sr....:41c, � 3'�rye#` �tp$' a � �7—,,,,-', ��' '�' � 'x ' 4 ' v: � i¢� :'*^;n � ” 'k'.,- fir, , t �^�fi r'"` , ` .'�' � '�3 Y, ��L� � � i` t 'bF k A'K ,a 7s>,�, L v�,,A1+1��'tt �, °`#� � '#:,-.'''''5,:'-':� �`�wy .e '� m �' �� R--;.,, t ��' i tom` ' � '� , x t .a '' 4"".'''''-`k m + r & ASS x� ti x _r.��cV .',V,_.. t:u ' ... 9y `+att, �n. I ir.�y ..' 3 Packet Page—931- 2/12/2013 11 .D. Q , w':S, �"i• n `v'. •,'R,y tei, � �"I 5�°- O z 3 ,y , � ��Y � ,s �x I y �. ! e�g� « i✓ yy� � 1,,,,,k'5:!." « a a a� �'>�,�K k" it;',..'i4 R_ �N �" !tl`* '- �� «� � � z + ° � I �". 4gys� � 1 i .� �r � �� > #� ' 5 .Ar'' r.s" � T s"a »,M;r w�, � X,w r � l xri ? �, H;: � ° a�•� � A�« o r" : '- ;+ � t g, + �, ° •� -- -v r11-5T-.-.- A' .: � I r � i ..s , > -.' ' , I , bN a �� O a ` a ue . "'4 R C ry . ‘'..,t,' , g r 4. � r a s .0 a• r.,, ib' g , d f m .f Idn .aa^ :u +2 U F lili ,tiYrc, Y� W Wµp a F} E S • � u � k,7 ]� „ —4 ' b * W••T a � ; s . { a_ � o r � i O fi ' yy� 1 �6 y, "t ° f:, � ti,„-. a,. i4.1" Y r s y » �nt� ,` \ e r\ °,..,..,.&'.. y ss�3 °4 + �,-: ;{+a i O � A x o '"` t "b >, Qd v " KK I m .- d 7i. ¢ n a �fi r �g I 4.' ,a j „ ' " t"x a F- 4''''''':1;.: k I L 3 " . O a y o is ,�� VVzF- f R„ k 1 ,, w x°ti w: ` '' a � ; ? ,„„ ,":7,4 o °. i ,� f) tt ,7'ins u y d " E oU Paz ` 1 A ,V 3 xt � � r „,�t w� Y my- : m 21 ' r s a 4 t�� , e ',,,4„ :fi .I �r i� � fi t 1 ''.4 N ,i� c � S t� 3 r , + '. °��' � i , a .. ie k ' .1.-t'' :p. <•'•4 �*ks ' + k,F ' a h 'z '4 €ax ".114:,,,t:a Y wr n � d 4 ` �' k w y '�a: �h- - �'� a ��+ . . • 'i 7 t,. qq r ,r, - � ° 9 I df gip- r 11 ' w 4��w 5 e ; .z ; ° • 4 � a tF« ' , , a. i ` g-`a» t ''t'''.-1‘,'I'..,•;',' d� a� i & ; -. t1 s' ,;-.;i,.11,...4,....,.. • ,.. E,1 ,e_,—.,c "� i a ��.f + , R } X3 :r :B"` «'� , ' ' d' 3 e 4�> "-a I T ' r "-' 4 �, ; 24�. .a „ ° ,, ', ,;,' f a j 4 • 4 •'.''''.;, r a 5 4 *s t `� '�; s"N .."'it—x � �` x4 1 ftv v a .4"y . -Y a m 932' 3. r e„c s Packet Pa g. Pac. 2/12/2013 11 .D. a . .r a` e r i �a��'.,t ,. mit i �.3p#•-",S ,,,',,a,°•+�`C",h Jt: . i' W�rt• N f a ER .t S .. .*`�T e t y o- '..It'.'44'-*...-441 pp l, R " ! m-iR - R tlIC 5 F4 `"` "I . . .: r'" I q ;uii: �,:ft....-•: !t *�� J � F �i fi , - � m � IP�t r'i .: K� *'"v; E„+ l' *r } s ., r{ Y. - .,',. ' ,�,/i 1 � Y ,'1,1",t. }JrT '✓ ,rr X4� { '::::,,,,,,,,'• p � 3t a+a .k a " 3n,I, '''-',-,'',•-2,... Z . 7;S�y .a 3 .v . �i I � YI d * Y 3 h` N 1 I = s,, hi t,�..�a .w E 4 v w 11 F ;` 1,' a.o ,° .° .s i W x. . m�x S b- o Y O r s S 'S.o 9v:•`,fie'T eT>t . : -p• •• 3 a R ! r . f � y o N W P 4 o ; . M'- � �', 711 ma 4 -'': a, :,1,,,,,,;:i t3 : �^t- , ,r YRroz 7 -~'� :. l# .•.•'"-:1 • ', `` .�P: ' .� " f ' a a ; .f Ma �'K� a yd � ,.,s '11[ Z •' t � 'It-,411.4%. r 8E,,,.3 1 e � J� a hasc 9 { x t- f ? t b y_ " 7�« ce., f � � s I x ,,. m 8'1114 r? F 1, .: ' a w ':7,:$,,:!...,?-itr,,i ,:, ::k',-,' : , `',?' ., k.,q''''.A:,-..:004,Ar:ki4;-::::;.,,it qq�.: 3 '4-.'{) P+4 '1.,• i wrw' -:KA v it , 3 :r . t. p'' ` � " a i V, 1 3 �I _ €Y�' ► w P 'k� `''-' ; t ,[ � g 1 1 �1 s 3 s 7 t 'R X1 xtrvn LOxv3. x x avox� S s 4444;� is T 1 R 933 ke Page s Pact a- 0 4_,.,' ''''''4.., , ,,,,, .• 2/12/2013 11 .D. d _ cQ y ."`i_.'"' a '. "...:".'",ft,,,„A t -,,,' :`,.''` 2*. �x .�„� of a.x �u <:. 1 oz .- � "�' f4 �,.yx 1!.:-'' hr {fie .. t* .r7 1. O�c T '� I' 4 x w'ff 6�' I1 .: s ,, ;:: —` ee "_ '''''A,.. as wry ' .� ,�.a • E. tlx! � U .4.,A1.,•-•::,,,.,,,: # 4 E 4 �+ d C .h- � _ � y p Vl Q 41 F-u tr � 'n" Yt „� � � o Q y a o 0 u . fir,w n g s�. +d tr,4 a�1 W— o • r U d! 4r ttl Q O ] Y:. 'r 0 0:- �'� A s Ili'y t "� ! / 4k : w �' ,ffi 1 k., .. W of d ' - � o ' :5. d 3- g> s "'.'ice -fie ,�„ w . r � g, 'r"�'. "tom � � � { :',.:;','".;:5. ! fir.c � ;s, � :,'-'. ox„5 s 2x°1.1 t N „',;;;;,:4',,. z• .$a '4.',.!°:',..A:::::„ .k ' of .JI O F z`2 m@}E p• �j2 ii, fi e X•i t',.,:: � iy w 4 'm :, 1 ' L ..„:2,,,,..,„,74..., . =.4-z-t,.. .,,,._ ,. 1 Packet Page-934- 2/12/2013 11 .D. ..1 - . . -, 11„,-, .."':',. : :.•t'' ' ;;,4'...,9''.4'. ;- '' :‘;;'' .'.;.t 1..,./.":".'".."-... ..• ;"-4 ° ;'"; SI kt t:Yili-,1'.:1"-;"":r:i l''.`':',',7,}.!''''',:--,„;.....,'::::011:!:!=;114. :4,4,4.-,,-,4,--4));'71,), ---)-.<)-:r--.)). ._ .Agwo p:,,t,': _-_ 7,,,_:,,',f,=:,54,,,,,,:61:::,,-;„ i„,:,, 1:,,, 4 jyi.).) ),))))-)4),,,Tov:7-',z ,---- :,,,„)))))44:AY)-: .),)).,'),.); ''',:),-))".-3', 53- : ' .• --711-?7i'•;"`. . ' Vi' ••//'''''';',- .7 :# 4" , -. ,-,:-'''',"7";:: ,.. .t' ,;,'''7=i:-'" ..- '•;:',/,- .;;, , "••• -/..,,'J' , . '-'•,' I' ,, ;,----.1,4,'3 ,..;.e. ,:9.;4, . *.‘ , ^12:::;',', 44'''''1;...,#'.7.4. :';',44;; 1:7 -,.''.; , KR -,-,1-;,..-i ' .---/- -7-1.;L: ,- i- , ------' :;:!,..V,=',„ 1 , ‘ . . .„,-,-;;;=-...AV---------- : z-....<-: ;' ',-.-- „....6 ..,.,. - - ,,, ,t, . , 4,-3., -..f..-.4..-:;.-" ... • -- , ' '`.....'- f.f.kk!'-'1' ',',,; /-4'';4-----V- '- ' ' 1 '''''' ' ..:'•''';;;i'q,44'....'''' ., "; , -..,`,' ; iv..f %,.,1,,-,;'" 1:', I% :,,.:,.',,,-7 '; '..:-. ' .'. .,;, . H *- -, ■,:l., ..;,,,... , :.;!,,,:,,-$':::,..-2';: 1 ', kl.,,,',,,, ..,,' :-•:,.',.:.: - ,.. ,,, --.,_ ,,y,P47 -'''''•-•:=',-,.,0 '1.1 -41,:j-,;,,X'.., (:.,,, ' • 3d g . i I t . - -,,:.,T-_,,,-,,l,f,,,,,,,,,,,„;p.,,,,', Let; 4,13;:::::,.4.,,:e.4,-,tii.',4 .--7,,,:-.--..'...„ ,,,, ,, g- .,,':',::.:,...?:,,,,',.;,,,•..,,A, ,:,,,i,,r,i rf"t -...a,:e..'i*"-,;.,'yl,..., *,, ,,,-,,,,.. . ''‘!,,,::;",,,4rIfff'''.‘ . , , o I . ,,.....„,„:,r:,,,,7.tiool. , ..,:,,,, ..(...*,..,:-.._ ,...v..4,",,A 4,,,7,',;iiy41, .,'". ' . . 1, I'• ",,. '''' - * '°I' ; ''' '''1:,,, ''"':k ...'f's". , 1 ' -'-'i,' '''''',0ii.i.." ' :2-*: ..%74-4:4,4.' -T4-'',:kittr,tri.. - ' '..,,,' . 0: , ',... .: .' k, . t I 1 - ,/, i -.1.`:r. ' =,:.---.4-Aiii,v..;,, ".",p74.,ir,:44,:.-'...7k...4,,,i:... -r'''' s.'I -'-':,- ' . f -' r '' ' .: . - -,';‘,:+*-,:,-,A1 " - .'..q":C.°,,,-....?„,;t.?.441-.','4,.,' '-',. , &-i 1 ,., R--- !. , ,I 5 1 - .';'-::;;:t.r■i"I.1 .;.:=:1 1,.:I . , '.4 'i, ' '7C74C.:1t. ,.'.• ..; 1 ; ! ' 1 t '''' . -iitc.4A• :: l-' ' . '''''' '" ....';•:'!'''',/' * 131t;t:M*/*,.. ..'- : 1 4 :'`-:-IF-'°* 1.41 - 4:: i,,,LH;";L.' ,:i' ,,,,,, ,, ,,,.2D.-:„:::,--41t:7,. =4..01,,7.er„,,,.'";,1';:t.;-,A",. -.' , , .9 If , .!'"',,. .5.,,_ ..,1 i z ?:,,:4,:+'440,ititittie '.1 i'''' l';';;!-: ‘.'31'' :r72:".:'15:4;',.'i- -.-;,,,,ri,',:1;417::*:„. A.V',, ! ', ' I '''''.4.W.,f,. 11111 4 . .„,..,..„....,„i„,..„... ,. „,, ,,.,:,,,,,, .:.....„. .,. ,,..,...,,...„, „.,,,,..,;,,.., ,.,, , , ,, .,,.,...,,....„,:. 1 ,, . ,-•':!',4`?":::.4-L',.'' i f /o'" 4 1 .`-'1 ..- r :4.,i'l ' . - : ' ' .. : 14...,,e, :..-,,r-,,,;,..-: 1,;,..,....' . -,4,4*, ,,,-- ,---,. ,,..7,, .--,,'.. . ., ,..i ,.. . , -...-444,, g.,..-.,,vf:4 f,: ..-- .,.-‘---,,,,,,,.. .: ';,,,,,,,;,. .4 ,'•';,' , "`"?'' i7-'''''' ' 1 .- ,,,r.. - 1?,', '',4 *.., f•L.:',1.7%,,,e0.1:-..,'Of '' . ' - f0., ,i7,3*, 't' '..- ....,.,v-,-;, ..i. .z. 1 -.i -• 4. ,N.'"-'.'Ir 1;":4',:;.,'.t,,,,--if,' ., %•".1 ' -, t, ,4,1 ,14;'; . I " :it r, l, :,int. 1:itri ))))),40,414,., ';,,,, ,.:,:,, - ' ,,,°-,-.--)s-,- iti;.,):::,,, ■ , ',.,.-/..,, ,,, •, t-*,,,,,rt."..... i,,,,,,,ii!,,: !',,,fL-;.:::.1,4,,,''.... -', ',,,;,,, ! gli,,i. -..r..„, 1 / ,,: "1 L' r"Y'V' ( i ,„ ',';`,,:.,,..,', 41,,,,,. , ..,.‘^',. -,,,,,' .tx., - .444,,' ,k,,:,, - 6- -,- 1 i.-,...‘0„,t, 41 :,..„. :Ara,''.4::: ,-„,-,-„,- 1 :,-,,,,‘,:„..'-**mit - .''' ' lv.- ,rt,',.. : ..- 1-''',„,",,14:'#'- ,;,"-.", lo• -i r ", '-/f"l'''' ry.',/,',.:;4',„•;,;•/.. `,^',' / ',,,'-;;•-;/*:..":. .,,,'/ft.,Pr ./.. .2. •,40,.'4 '''Tt -4,;•• : I •., ' •;,;.„.i.• /:;•/:'.i W > '''• ; ,t4,(..!'''''' • '/-•,i .: ';•■W. . 4 ' '''' .4' ''.4:4.'''.;);...4-1:4t,''t 7:- -ro I. •.. i .•,,.Iv ---4.11, z • „,,,a.4... ••• •, i 4- .,.., .41-.,. , 4 ..-',A' .rlir, it-foc.e."--1-.,''''.; ii.9,''' ,' 1 . i ,?t, , ,4--t.1- ,,.:,-tt - ..4........%vi.ss..-1 ,4 1 --,‹ ' - j ,r 1 ,...e.A.ir .!=:..,k,:--7 ,...,-,s,:.:,:,,,,, ,,,,,i,,,,,,zo, .-,„,',,etr ,,, 1 I i "-19 ' '`.1. ,4:,.,:::W --..-'-!"'-',A::%' ni44.4:0 i4 4--''''', ' IP I ) ' -.: - --" ..1".:!' '4‘",i0V1V-A':',.::: '' "Z;-.0 -:"tf,:.'- ',';,,i'"'*- .14;j. : 1 41F-,,,,,--..,.: , , 1 : , ' %-: ".iotz1!-L. .' ,. . ,, r.,..4 ,,, _.k., t•_I I:,.- ,,, .'; .',;,.. 1 : 1 :.-:''; ;,1-P;4:.' .'A. '4:;:');''' . • '''t 401i-,1'7: .;;: '-' 2".,:i'l.,. ' . ‘;A I „..). . j E. . OP, ' ,,..),„._44, ,,),)..), „),J)-). ,..) I.1. ''. • ..4.77":4..1 ''' '':..:1': '''' 'I'''r"!;':■ '. ' .■J'A.:‘, ...94," ...-.,:i c, . wZ '''7,;t-:`,1ir '. • .. - c° '0,4.!,:' 'f.:+•:.,« :;,-;44...,.':4.•N.,•,i ; ', 4. ' %I:4'1.144M '4;::!rrg*-...,t '.144;j4r4;';; '1'4 .1,,,. ,,i,-icr_ ,, ,,'."''.',..'•'-',,•;",;',.;'-il . 1 , ''t.,:ii" ,,,ft:4 ,,;:-46..' c_i , s..-"*.c.;:44:. ,:,:- ,-21, ,,, 1, I Or!,4044,....,, -.If :-,-.1,,,, .-1. I I -.;,..... .fiit- ,',:,,A.:,.;i'.7,!t , ' ) ):-.!,11 ').;').:), .,...es. „Amok 2 i ' „:4,,,t,:--,::::: ::;,. ..: . I 1 .-,;;i";%.::: - 1.'14**-,:":,-,..---", -::‘, . ":-;..4.f,..(4-;: :._Li"-.-": 71-'f„": 0■-•`°...., ":„. ""'-..`' i*04 -::. .i.,,t::,.',•'-'''.., '-e" - 'g-. I •...-• •..,•=., 4,-. „..„ ,,,,,,,;: ,,,,,, •,- . .....,f- ••,:,# , •_,1 1 .:4,,• , •• •••.•• •-- ;t„,,, ' ' ---,J.,- - . '••t' .'.°1° r.4 ,. ;4.'.',..'"...;.?«.;'',i:; -;".' i 1:, ,"4:'),,4. .";:•‘',;- ",,.." .J.I/1. •';,11.:' it; -. . `;'/:' .i.‘"'',. " c• ...:4„., •• ,- ,f...4.'r.,,,„:;;:::,,,,:l ,. 1. ,,,.. ,..-.'4.-:. .,:v -..,:,-f :.,-4, . ;:v-f., t --.; -;',s3.- ,-.-'.1, - ., -,T-/■-• * .4 -"',. '.4,,4:',`,Lk i",,,,,:4) ,t):41"'"?:),' -,7,,,.)!):;-)•.).),)i '''''.0) ). -;,- ---; )).-',).A)---.• ))))4'4) 'i t,P.Att fin ,) ' r'''/'=:.',41,''';'/,1•1;r.: '''.1-,;:l,4•11+,_;N,..;::. '')n..,*')•'' .•4';;.1',7. /...„.LS!.k ': 'l':;:i";:!;,!'::.- '':'''..0'1 --ik,',4 .,,,, ,,, . ;:1,., ' E, 1 I --'7'4F)f);41r.:):40,-;-:,'!;%:it '')'•:).1),i'4`iir')))*);:t'').s:s.444° )) -'sl.'"=.tr";',i')))) ' 1),i )'. )tf':)''''''' 2 ()5 ' 1,,,,g,,P,17; ,, ,:'", ,,N1;;;4',411:7,,;:. . .. :,...., .,1,,,,, ,.-....:(t1,,,7, ,.4:1,! '....;,.' : i I ''''.,•;' ,-,1,,,,p,(.'.. ,,i; .,„;,, , ‘,.‘,,,i: p:-..ta, 4.,. ,fia,• ,,,,,,,,A,d, "k: ..,,,A,, ,. .ti ;•:,N,,,, z 0 p ig 4 ",' ...'..'k,.5....".1 1,im^', ' ','" "r"*"'"..: --,;:n---,"',1:t1-: :.*...ik=f:'-.,,:'- - 'f-r-`,'"z7, . - :-- '-',f4til-4K.r r,ii,..'1'7 1.c'Il'' i'„I''''''1-'1‘' 'J.!' lat'--E:-: ' -%,,,.r1.;'1.,::-P...c t- it l ..,f;, ,,-,:,.,1:4:,, ',..' .,,,- i.,,,!1.;,,,,__;;:.4. -,,,..--i,,:', ':..,,,,, 2.‘,, ix4,, 4r), 1 i: .,,,„•!-„[4, •q tf,;,,,-•;•,, • : -,tx"!:,i;--.,,• - !., ';,„--,•-.!•;if . 1,',..'...it:..;,,'.til':,14: ,',-,,s'w 4 .• ' 28 I .;„,-4,ay.„.. .--;,.,,,i,;:iito,,,,,i,„2 . ,,,,N.-: ,.-',!....t.-.,•, 7„......))7.' )')).,.:),:.'gi,,,,, ' ,),;',-.?),;:tijig_:4),Ifs,...)), ),:)::1). ,,r,2,T,,;;;) ",- aq ;-i, ] 'Ita,,), , „..?4'-z.-V4,......;:72,' ,,-',..:,.'1'.1 ■:';','1(.:g7ta‘ a' ."'34, -L;'.;-.,:,',,...''."-'.,': *ilf,‘,-..' i a;:rt -a.,'11'::::34•1k...4i-- .:" --47P,Iztaa: : i ..,:aa ' ...';',,Arle''•'''.,4' .•,.• ', ''',1,•.•••, , ..:,.' .20.1,,lm,. VI, 4,..,, ,I, -,'4-,. .,...z,.....- ..„--.,,,,,o, ,, 1 ; .,,/4 ,.;,,,,..;.,,,,./,;•,,t,, ,Ittn,,,,:,,,a,...„1,,, 1 ,,..ii,.",,,;:to.//,;-;:t-,,-.,••••,-'.••:.,,",,,,..y...;', .../7.,,,,''' ,/,,,,,,,,,..1., ,,,,,t-,4_,a...-"""1,....-' .„,,, ',...4....,,,..,.,...,„, -- , ; .,,,,,,,...•,•,,,,,,,I• .•: •••,...,4:•,;p--,,.?..4„.,-,., .•il .:,,___t_,.,.,,...... ..'N .•.:.1,,, ,,k'4,-/,',•• /ro•,,,F4tri.,4,:t e---, A.,.„,141. :,'-‘'' '1'- - ' , , :'''''''''04' ''''i' 110:.:1;t,' ' LI 44:'--' ,":.,'14::-'1',,,,,',. .; '' .:',:'',:,'. 07",Wr:-. .--.-4-:ti*.'n--„',,f,'-.T. ' i , -' ,-..'.•„. .,,,:,'...y.,, , !Itis..,,„. . .,, i Al 4,_,A.,,ii,'Zi`,1',„, ,:L,,,,,r, ,.'i.';',11.".i'IL',...:": --„ :.;'.-',,-, • ',".:17.:"...4c.,c 'f!,,1,4'T...-'-',,:,. ,, i ' ''. ,",:.;i;4'-' ./1/;.* ,t3T:i. '' i a II 1 I ".•. : .T.''''•,71'., •' . ;"- -.1" '-.T... . ..:4.v.Ar44._, ,,- ! .,....r„ r.„41,,. „,„A.:4v. _ . „. /1,, .--,.-,...it :: :-:,-:4„,:- ' . . ..0,-,,x- - ,-. , , ,..,..,..„,„. .,.,i'-0-14*:i '-: .1 -'' :4-;:..s.:'...•,,,-",14:1".'. :1•::.‘-',1".‘5"......ii'i-- ; • * 0.'31111-•'''':, :-. J •.,40;/;'1:' '1,41.,,;:..',Ir.: 'i.,,,,;,:-4 : ;,,.'.,',,,-,. .II - r , %.;,,4!'' ci' s',4-,!,',...,.4,::::,:-. - ' ".- a ,...,, ' - ''i'''i siti .'',.:' A.,,,,,,, -,,,,,‘ ttv . -1.• -.....,4,' i 1g ,0 .....,,, ._. .. _ - -..t. • ili„ ,- ,,.. ' ';',44'..,-4,*,.: ,, ' ,..ig,-:,,c, : ,.. ,,.:.,,-- '''', ..„.'"':',-t.).:A",44 P••• ,-,,.,; , , .,,,',•, •... /,,,,,,,,, /...,. ' ''*.W1:4 "'"i;17.'' . ••••,••• V:.*';.4.,-4,.' "/. ,•,., ••-'• ": '1"'''''':•',41.7.-!, '44.*K,,,..';,,'••'.7:'°:'7 .„--, -4'',„, ,„„ ••••,„,:r.4:-'t r..,..P. 1 i:s. . r".;.12.1 Z.",'w-11 liliii-, .44L -'-‘ :*'''> -''' ''. '-':::: -..'.•,...-"31,4';!e're' :1`'.". ' ''4'::■,'"' '''''''''''a . .----..-...„ ! ,_. r r,,,,,,,,71,,,,-01,y,r.li''-'4•Sr,',',.- ",,' ,'`%4'-=. .,. ---„,,,,. ,,, ,, , _... . ,.. . . . '-:,:-",:.:,.;;-ii.:4_7T,;;!,1'",:,1-::$47' ,="„:::,- -.... = '.''..-•--. ' ...i..- Packet Page -935- 4 . ,,,\,,,,,„ssuon, : 0,...-,,A1 A.33VS OS 1)10 21011990111.11\111 91 91;6 210Z/LZ/9-61•11 fnd , D..191\5133,099 Avrowoa\ 1 , 1 1 ; 1 1 I 1 2/12/2013 11 .D. - W � w ' ` i.iyiM h+`5 N M > pa. 2- y fi . ,„:,..u. U14 �y f 4a $?. 1 aW � 4 r WAR EF i ��. +� � !ca u t � 'a vwt saa:aai �,yy p,, e e s!5 y 3 ct;C_ �,3 y 9k� � n rn U H W LU i " pf v� f 'Y xa N 2UUI - 0.. �.� 7 '1µµ -4*-' 1. �. I V41 'y^� w� 0 NP Q� �uc w K� " s co,_ .m t �u= n .a ♦ t A 0 0 3 u �r .,-.Q.,,,,w � R'r if': � U� U A W� , �t ski E • ,�. .`, w m-'m r. d sk .�,f¢ '& � i +"`,."3'. 1¢ ^� off,x° 8 Y , �a® ", id's w. p ,�, c1wu : � �3s �. 8• "� � ,te.�` � �'#: oaGx--4 3 �. F iP" O U s2, k fy, Y\$'- >t sn'3r t�if J �A �c a y +e 79`8. @ N(. ot i Li nk n 1 *°'-14,01:4!..1,1', 3 g 9 q3 1 ill E-1 �i :,�' "' :#,:ea�''^'sfie€ `: i 11 I r rot 86 6 LIOZ/!Z/B-6xv bt Clld yOHSMOWWI\sl!o7a0 A��d\!A131tl5 ON 331V„OriWi\tW\suv!�»ualxl\si''r°Nd. MO6Otl\"r°a1 u5!cap\6x!nau!6u_uatlo�odsuo�i\:� Packet Page 936 . D. 3 11 - 1 2/ .2/201 irD ,._ zp, , , ,.:. .. ' r. SI ,, ,,,, ,,,., ,, , 4,„ ... ,..,:-., , I , yt !Irtf . ,„,.. ,,,,,, i . , aaJ ... __4,„. p , .. .1.; . ,,_,-,-,,L ,,-„.,,,,,'/..., -:-..,,,,. :§iii i : _. ..,,,...,..,..a I a. . ,,..,,-,,, ,..,,-,„„:_:;,..:;:, -,..1 L. ,• ,,, ,,..1,-.7,,,..,. iL:'? :'--. f:',' :', '.., _, .4, , .1,-.-,,,..4-,..,,fii..-, --,, , 4:4,, vi • :.1 , 1.• ;„,-,,..'',.'„'" t' ',1. +';i .;10'.''ir):...1 --'..-e. ';',',-,,;:,„,-,,,,;,;,,',;-,!-, , , -,.., ,, 4t- A. . ' ,,,,„,:,,,,i, . ,c,r, —.1-- . --,,,,,..-;4,,, --;„4 it. :i . - :;:i' ,,,'1 ,':.,.kii...-t',.;;,-• •. , ' .-•::' f."'--, •'..:;1:-; ,k.z.:; .--' -', ..,r 14 ....,,..! . 4 :,,, --_, ,..„,-,,-.„-t;:, „f,-,. ri ..) .°`.,1A.,'".t.'•:.:'i'..,',...4;''' ..;i'4.!!''',.. ..i..7,41j;t1' .-,, i''';',.'--- ... .2', i-,, .-4 -1,,' ;',,,-,!404, &-a.'.- ,•‘. ..„, ,-41'11t7k:I"'11;:..'";'''=i""I''''it c.'7'4,1' '2''''''' ,4:14-',';,-,,,'i .t,',.t...-., .'t-4,..., „ , . .4 .,,„,, ,r!'ti il:'':.:,': .:i:' ' , :-,-7.-1.,.,.f=' ,-1-4:::04,1;Tk \*., -:41.ifil-,.:,;-,..,,,,::,-.,,,::'1 , ,-;::,;: ,,,, ,,,,:: ;,. ; 1. ',•...:, 4. .„,,,,,,,..,,„,„•:,,,,...,, , .,,,..„..„.„. i-4 , ,-.,,,,,,, „,.......„, N,'` ,_ '”' ,,Lt, - ',144%. ;*::":1::,,. -:.....; ,:',..',.';;;',,!;!': t ,i,t1.,7s'itz;T C3 \ v;:ij'',;,:- 4,:.- Z.i. .-''' ',..1.:3..?: . :i . ,) '-'7-,?z,,,,:''''',1,--Zit"`.111- J'-,-:';. i i i 4 I vt,4,..,,,,:s ..„,,,,7:,,,,*,„,,,,.:71; 2.i.,.;,,.4,1,,i't ,,,,'., ,,...ig.,.',:i.0 „:„,„„,„„,,,,,„.,,-;,,,,,,,, ,_ ....,.,,„,,, .. ,,..,....„..,,,„, ,;,..„, ,.. ,.., „ ,!;',',4,'5,,•-•',3-'.,,,,r,.,.1'..!..1'''; ,, 1 .,, ,—,17],',i- ,.".,:i !`"il:c,.:41.j.' , -:=.. ' .,::;...,. •- ,, ,,:t.'-...;:*''.:17:-:::;;T",:: -'11 '' ,a ,.,,,,...,, .., , ,,., , ,,,: ,,..,...:::::,:,, .,,.. g ,; :;;,-,i- ;....1 . ,,,..,...., ,,J.,,t.3.... ,... „, „..„.., , ,,‘,..,.. 1,,,,rt. , i,,,, ..,,,..,.....-t'::,..11,. . ,...... -,.;,,%.'t „ ,,,,,,,„:',1,;..,;t4,,,,,,;.,'!: .-1-1 „„. ..' 1...,-.,,,,--%-r-...- .,..,,, li..I..':„"rf'$24r:S 67.,,,,,-;, *, ,1114..,•:::' ',,i, ' N ' .''. ,1',"'",.,9",* ..-:,:q.,,, '14- c= A '.' r,','E,,,:,-,0-14`,•,:t4r ,,,:',,:,:<:, ; ,...--fc,,..:::,'.iii,,,:;;?:: „ ,' :,,- Iiii, ii,, ::it-',',:1".,,7 f.-'7 I i'l, 16';14',”'-. •-ti"'--, g,,,Iii'; -;;;I'''' ''.?,3-' -*., " peC) -; 0 l'''' ■ ''' : I. 71....el'N:'.':.-.1,:';'- ...,..0 R,.a t 1 ,.1!-;,:,--..f.;-.- .., r..,,...„...'5',.',‘,..r.,.., "1,t,,,,..- ., ,..'*•. ..71 ----7-1';'±,..... , co ,..,, ,.....„k-'..7;;,4,:::,77.:,'Ife.;:,'"-;?■.4.,,,,4„,.,.,,,,,i;:`,::,,. . ,,, ',:,5",,,'1.:,":„., •-,,,,4- ...„: ..r....k, 4,;,t.,:,,, . -,,,!, a!tt.:--.;,!:- a ii,:::,,,',.!i4 -,,,1:-,'-;',,„:1:' _-: „,,..' t: ! ',;; ;.. ''' : :r„ .,, -,?.i„-..i.,"', ' )., !!',.,'..:!'t.'-';:,i, i 1 'r.o-- ::!?A'.4--ii.'-,-,-.''': ''',-::', ..,.'?..1„,,,',.1.,'...Q iA{i'..-"4:.,'',.;.'- '1-if-k:-.,...;::I't•-:74.-.' .`:i-r,„4::.:1',.,:17-!: ri,..,..E a I #,. `..7„,:..1.7:,!.' ,7*,11.. •.„,].:i':','i',Zi,.,1„. .,., ':',:lN:.:, ';''-; 14:'''''''''..:°°;;; ;:,--iri:;°:,:*,''''',:, '''' '• 1.i ' ‘c:ili'r...:, 1,:--'1'''''•!`'..:ilit't1:1 E I i i i ti ,,,..t,, k.- ,;„,,,,..;:ix,ITT,,. '4,54.;7-.4:4' -1,...'51!,,,,,:-;,..-:-,,,,',44,,, ,,II:tiz,,,,,,,,,-7,,- -4',---,•,„:1-- , ,,-,if,i;cl-;. ,,,;i;,.,,:. '',4t7,,,;,',,--,1 8`-', Eli i :, , '.-i:14,i?„4,....,,Iiii ,, i'= ;1!•‘.'-!1,i?,.'F ;,.. Art._,,,,4,.;';:?-'4;:,::,,, v-,-' 0,4k;,..tf4,:. -i-:,i'L ,;1'.v,i '',' ,i'-!. :4'. f".',ii ;',,,k °L1;1 0 if74,i1,,,*:$.11,,,:1,,,,;...'„ '..z::. ;',',..,;,,,t,l':,-,.:-.4*,4-°"- 4' , ,ti.-4 .'i. " ' ,'7,,!‘ ‘:,. .'i•I'} ';;.;',/:,,i2lrii!IT'''iPt::";;',- '''''' ''''j ''''''''' ,r,'",,,10;114:4$4::t'''' i ^) '':-17';,_,';-* -7,i;,d.1;7:1,',.4,4°"''`.:,...::.r,, 1,:°-!' .i,1'.•`;'..4.1t.trli,:ki*,'.2 i in 1 1 ,:' .' ,'::-....-:z -',,';,,,,.'!:'..,;;;;,,:.:7:;,,,,- 7.4.:Iti.,,,,..,:-,::',..:„.--,,,,'-','i'i- ''',' 1 : ..,.'•::,''-'.7..4.,-..•.-!;,,,ii,?2,,cii ::,!! ..„,.-51:,,i, ,:ft.':, -;'. t--,,,I,:,;yv,' ,..:,-=-,;51'.:..., .11.I -,,, 24.,..,:..i,,,, '.1 ,-,,,. ;• '..., .i.-','-,,,:i..;ft..;,„1,,;',-;;!;;.t4;;',...,' 1 , ',171., ', ' . .e.-,,,,..;•i,,;*;„ .-;.. ,:::"El',,-,-Ti.ii.4 ,..,1.-,",!'4'.,,f.;t.,i, 1;4 %,.:,..0, "''''''',e,'`.---C,'.k,•'----i,,V 11 'it.„ .,,,,,,,,...,-.4.... .,''''i:',_';..f.,' ',.. ':',91;;•11;12',4v,-'.: .f.'1::-9.r I.',--P i4 ..g.,, 1'', -5 441 .4,i7.,t.,:;;,,, pa,...,,„ 0 llii'4-it.'fi'...,k',,, „,6-..,,,, ; .'., ''i li,,;"::'.,,:''','.0,-c` .. ,2.-frIt ' '. \ '''' .!..-.4.]:-4; .,,,o.,,,,° ,.,,,, :f..!:,,..,; -, -.- ,--.7:-::—,,,,,,— '. -- . 37, - ,,,,,,,,10.1..'-'',,,,,,,.;:,,,,,-; ..: - ■ ' ti' "I'''S a8 Page 937 „,..,d\` t pag I „ro''' '' Packet c„s,'° ,,,a. 9_6.P•g` ziozi'z „ . . 2/12/2013 11 .a ,,,, ... , ■ .,,,,_ -„,...67.4e4f(i-;, 42 , I- z,' '-'' .-'''.'-= ‘•#-'''",-,',' g I ---,..--- ,-, i::, 4i4PY*--_- -1',--,,-,., -r;. ' I (_rJ 64 ....,, i-:',:ii.."74.;;;t/VT-- ,,..-:3t=7-,;,:,,,`;:;" -7 ','' 1 2 tl, 1 III .., • ,' '.':4;.„'..,.<',..'.;(4'cli,',F,,biiktit.if.,""i'','„?!.,'.. ;;;..?„„,f,z;..74?,,,17 j,"' I ' Lo 0 -.e;,'Fk7, ''' 'I' 't ",*";*."- - *''',,*+.'1.i*f*,; - i,.;;',..14‘t'' ...'•=T:"..'1"*.I.it9:::.*,.;,(:, - I.- 1 i ,...6 \ ,...,„,:,;'70.*.,‘Ns4*-4.,.'"'',e)411-,t.k,':' ',F,17....:.;.,'''''''':1.',.:'!„:„.:*.:;'''.:4?- It`---r 1.z, L'il ., FP . ..5'1 ._ .,.,• \ ';i4L',4"--,-. .,„it-'14,'";,;-.04,;,"~1 ' 1 L;,1!Q 1 ,,00 , ...,.4:--1"!!10 IL 4,14?fr.,.:',, ' „,.,,,,,„.., ; .; , , ,r, .i — w . g.... t;I: .7.:1:-..;,..,ait.*/...0,1''''f. I , ,,,...-, ,. - ‘'7 7 • 1 I ''' ''.'” '''''l•'''' '''\ i ''''''''•''''''''' '''• '•'''t -4'''''''-• "•I'V.;‘" 1 :;f:"1"'''''''': i t ii.',1:',-..;=;;;.',,.;',7,)i.,;:,;'., 4.,,,','■(-0'. ' '''''''. '"-.-.'.44“;!.'4.,.e,';',,,*,,,,,,t...' f..,;4 1'04'4'1,, '" !-* iitH` ..''.,-Ii,-4.'A, . ' ';,,F;4r4 L,".• ;I 1 1„ .1 - - . 'LI,* ,-, K I 1 L: '44,",,-4'. '17• '',.- '''r'''';''''''''''';744:4-1'''''''14'41 '''''•1:::'''' it ''';',I.,:,, :,',::°j'1,,..,.%,.„ ...,21, i,, .- ,,4.11,p_ I';` * 1 .5,.... •,, `,.";.,„, "'''.72••;,,i,-,..; ...V -,..t.,),' S,°•,'V `-''6' ' ,'",! ' 'tr.4 44--1 g" •,e ''''',*:'•.1-''-' .':'•-•• '6'''S14.' - -''''' ' " '•':'' v' ' .7''' ' 1 '11111 . "•"*.- ..? . , .1.,` 1,',.. 1 '„?'.,, , '-'' ''''• i '' ' '- ''i".''.- - ''''''.10,..- ''' '''''' '''''l'''.;-:,,, '"I':; ''F''",",1r,. . ‘\ g , . ,, 1 1 1 ...,,ik :',1,Upt: 1 'i.,;-:4'. ''''''„' --.' \S '.-.co ii4„f'4,,, ... , ;•.,o'',.r. i '''''''',;. ., -6:',,.,, 3' '4'ft.?,,,:i.4 tthA- ‘,"'.-. ' , ..' ■ \ w... V.ti '''''• . .'; "*,,,-,:::4 ., ',07i''‘, .:; ' Ti.r.:'..'4.,, . '' '. 17" ''''''.-, *:"'''^, ,-;;--..iig."-.---:11:, 1. . i t;- -4:,,',..7,,,r‘4",41••:4*.:'•''. .' — ,,,,•,,"•74"-7• ;.,,,,:,':''' r;..-%, ° '-'•- ''. t''--;.,' 1 '1 ',. '''',•16'4.1t.::.•!..3 " rAE' ,417,1„,,,,,,,,„4 , - E).tot,t.„-. ti.--.,„ 1:.,,,,,-• 1-,,, - .-,...,,,;,:,•;;,.- - , co,-,• -,.-..,_•„....,,..,,-,.. ,... ,,,, - ., , . -4,1„Pit'm -,'''!ke :.," ' , , ,, ';;'''''' ',;,q,d,,t4.4%';!• ,•',4A,i,-..)--:'••7'.?'''t.' '.:,'••'- -,.. 'i.•t...4 '• •,'''''''':,i' W = t%.-, f:.;,„.. 'Ik',:$..4 -.':.'1 . L".°.1.4 j:. ., '' '' '''7•; --.1,-,1! '''.',;-,,.....t- C4 ''....;..— i',:,,,,,...yat ;%,4,::..,''' ':314-.".---RA.,',1 • ''14'. 44. • B.-1 \ s, .. ...,1. • ,,i, ,i;1- .,,,,,,,,.4„,.,,,, ., ,... ....,..,,,.,,, ,63 - ir . 014,,1:.1,,,,,,:,,,,,,,..:-. ,,i, .., ,..=.11,,,, I 1 \ - rip" ,i.,- 4;‘,11-- . , ' ''''' , ' '.., .'' ,,v,'tk, - ,...‘, „...-0--mt , ::..1 ,,,11..7,:,„ L , ',-, \ 4 "''.;.1:.,4,„,...-.;'`:' '‘ ,,, ,.. '. co ,77f7;"-T-T;;;L:.,''',;'-'3',.',F4, , %, ‘/- y' .nft.„•!",,, . ..: •i _ . ,,, ,,,,N; ,.• '. •, , ' ., '':-r- '.,,,w4 • -,-,":L,',10,4.".'-r',-HA, , !, ' ';',',::: ,., '-'.:4..,,,14. .4.. \„ '..14. °- + 4`i-c • ,!lit,'''N''‘A"..',1".. ,. , ': 1' ':''.'' ce (4 rp * '?+*, ',:, 1. .•i c'a '' ' „tr'Sttl: ,.<,-,,'1'.'27r:;' .; ...' ,.•. ,'' tte iTi— '--- ',-,74 ' Ovoi-.) - ',4, ■n•:: \ ' -''',,,t l' ' , . ',441i- -'',2i':1 '' '4:.,..;-,-- ki,,:s' , 5' ,T,2 :PI. .03 .,,s,,,,,,:, :• ,wt...:;.; . =::=•-• , .-', =''..•- 2 „,-..!.. °:' :•• '4',..11,,,,4k,.,'” r Lg.' ' . ' , .., .; ; g gtir+:,;:", , ,' ' l'!:,,','-'4 ., ° (.1 c ttiv .ii-.,',,i,1',-_-.3 '''''' f-r...„1,-":',1" --•::'' .1; _,, ''' ;:!--"i', '*.i,,,, ,,,, '11 x .,•,..;04ft.,,ityiti;.,,:,'6, -,,.„ - s k.=40 L -ki: \ 1-5., -,--0,i,..;,,-1,;:J=..A,''.:4 i'i,_ • f-V, !'-4,41:,-;,:+1 ' ',i':,1 1 ' -1.' '..tt.:1.7i:x ..i.11,--17:A ...-ri „,.;, . '*-4,,,,. 0 ,,,,,,,,,,,,,,61 m .t,',.,_._„4,.,.,....,-,;,,,,,,•,:_-,,,,,-; „,„,:,,,,,...„: - \ ,, ... 24 . (^ ti --,. '-' 4,1.",';',-,5,'.:;"=',. 1. ,- ‘t,tili.5.--',144,-,75i, ;Tikkl(t,',-;-.4,-.;.-:.„ 044•3''.: 1 , ..- ‘,1 ..-,„„ 0 •,=-- •-,.,,,:5-,•:'6,';'-,, .-; -,,=s7•:- - --,i =-'7::-.4: 44 -' -.• ' -11'•'--2a••,V:•-•••04.,'-' ',r., , , ,..,,-, 4,:iiiit,; 1 14,-, . •,,,9--,7„,,,K.,_,,,::, c' ::.' -.:',' ',', ',:it.' 1 4, .;,-,.;::::-.;:,,:: ,:.,•:-.1,i--.. , , 4„.,,1,,,,, Al--z=2-' ---'-N,z.'-a•--' i— • ' -•-= .:•''.7.-i,,=:,,,,-174,z•-„, ,,z ,,,,,,,, ii,‘,-,..., -,441.p.,-- ---4.-,;:,,,v-v - ..kl.:;:i7:--..'...:;.: rIttr.o.,:,:„,:::,,,I.,4,,,,..i, :1,.--,:iii•;.,,,---..--- ., , , P,,,t.,,--,-,;(*".,,,,;,.. , '''-1-.."•!'„;:=1')i,5-is,s,===:4`,P.,:-.•.„;11,-'n',-:-7,=,=',;,,"' 7,•:, 1, ",,,,i;;;',..-:‘:,; '',,' 4- F,P4'-'. 2 '*,',''v'''-, ,"--;,-.•-,,,,... ii,....4.,, Iii,_'0'''-1:,•?..,- ,.. i;tA-:!,:q,:y:,:otft;;•,-:::;-...:,,-.il -,-. ,-, ..,,,,,,,,,,,--7,:iii,„„:4 Pi a i;;.i; 4 \ , , 1 ., ,,...,,,.,,,„-.:.,,,,,...;.-5";:, -,'-, %;;','''.r..''',.'7 ?4,7$0.:.,11,1,7.,. ', *‘ :'s`,,,,,2°,14: ‘Iii!,,--,,eL,1 ,1'4":-,.,`,`L'.1,Lti..% ,,,'.!,t4411,t1.;151: ' --(,";:,r•-,14:itt",54 -.'„,,,,,i4t.,,,,T --4‘.'41 , ,,,,', ‘,V, 1,;,,"/,;',,A-Nr'-',.'.k''.,., ,:"'',"ij'*: , " \ 1 ' .',.4.. .,.'..P'4"..0t.i.k, 3,.';'-* . m `.."'*%':':,;V ;',,''.16/ 4 • ' - z.o.,:i'1,-tirii,i4 .4. 3 , -,.--:,,44.--.,7-:-,,,i'.; -.:' --.ttiffs....,.. f.,,,1,,!..-,.,. '..44.,:-. k ' ' :,,t::,„,•;4,,44.ii;;:,,, ,,, .,,,,,,,,,,,,, ,,,,,. . .,,,i.:•,,. =-,t' -..„- ,,,,, i , ,,.. I ,-i-ligi,:74.0,!,;..';-. !,' ,-, ',,,. .', 4* '.'W. - .■L' L , \ , -,..,; , ' 1 ;,,\- i , .‘ t7 • L. , ' -.--;-'-':‘-:-, -:"- 7' , ' , ‘,.-,!.',.ri-,.,',!•t:.',,,.:.,?!..:7;44.7-,:,=-- ,, i...„ :.;';',, 1, - ...., __,.g1 --'4it - ',..,!'', 0\' I --t...,, •7'.4;' 'k<;',,tr.6"...-A.,- , 2, ' . -- 4.-rt ,-,, ': ...'-ig..4;.,1,44- .41;''''' ', '',..'i;`'.,: ..,„:, 1144 .0\6,,-.‘-au' l''' ' :-';'''';.71•'-,.. '''.--,"''''''-':' '.,- ' ' • 1 ,.,''''''-V.-?.. !,7-:14i4.- , 41„,\s,93road e., ilIVS - d dCH,mord.11\., *Nei Packet Page,,,,. 0, a ,,i, 6,, iLt/ 00 331 ACel.WV-;1;8 4 2/12/2013 11 .D. EXHIBIT N: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Personnel Category Todd Weaver tweaverna cacorp.net cell (239) 841-0448, Construction Superintendent Robert Peterson rpeterson@cacorp.net cell (239) 229-6925, Project Manager 84 12-5948R Immokalee Rd Paved Shoulders Packet Page-939- 2/12/2013 11.D. BID ANALYSIS Immokalee Road Safety Improvements ITB 12-5948R Project No. 60016.4 Upon receiving the bid tabulation from the Purchasing Department for Bid #12-5948R, staff performed a bid analysis which revealed one anomaly in the low bid from Community Asphalt Corp. The bid analysis revealed that one item [Performance Turf(Sod)] largely contributed to the low bid being $90,762 higher than the Engineer's Estimate. The average unit price bid for this item was $1.45 per square yard compared to the Engineer's Estimate of$1.00 per square yard and the bid of the low bidder of $1.65 per square yard. The Engineer's Estimate was based on bids received on recently completed shoulder and safety projects. The following bids were submitted on December 18, 2012: Contractor Bid Community Asphalt $1,904,344.00 Old Castle(APAC Southeast) $2,039,569.79 Ajax Paving $2,217,757.40 Wright Construction $2,495,539.38 A Bid Analysis with individual items comparison is found on the attached sheet. The lowest responsive bid submitted was approximately 5% higher than the Engineer's Cost Estimate of $1,813,582.00. Staff recommends the award of a construction contract to Community Asphalt Corp. for Bid No. 12-5948R—Immokalee Road Safety Improvements Project No. 60016.4 in the amount of $1,904,344.00. Packet Page-940- -I176-aged la1Ded F. CD 0 0 0 '.l N 1.4 7 0 0 N 0 CD CO C CO V' 7 C! e. O M N CD (0 (a CD O O ` O tr _ O V' < V' N N- O OO O • co co V' C C ,- O O O 4 ti O M fD N- M U) U) co co U) _M r` Ni m O O r M O (D co 0 t0 h O 0) 0 W U) F U) N. O h co O O U) CD CO O 1- < M N CO U) N O O CD U) 1- 10 N CD N C) O Ifj t` 0) Z N 0 CO. — CO 4- M O CD et CO 4- U'. N 4- N CD O co V O H 0 D) U) CO 0 N '9 0) O N A CO m O 0) OD C 1CI CO O O M N N U) CO CO V' M CD < N 0 CO CO N Cl- CO 4- CO CD O 4- O < O CO N CO (O 4- CO M N N N .- a N CO 4- ^ O " O .0- v v N a 8-a„, = Q N W Ni Z al 69 f9 44 69 69 69 f9 69 V3 69 69 69 6A 69 69 co 69 , 69 69 6A 6A 69 to , VF co 69 69 6H 6A 69 49 69— W V' •- ON- U) r CC+) fa0 N (p M it V. N N CO OND In M n 'V m .1. m N O IN O ((D V' 00) '- co 0 O V O 00 t0 O V' O h U) O O N N N N N 4) n } N n M t0 co V' V' (D O 0 d' U) co 69 69 CO 69 49 69 V' M O O_ C- M M N 69 M N CO h N 69 4- 61 69 CO S N 0 69 .- 69 69 83 69 M •-. M 69 M 69 0 Q 61 O OD 69 O CO O 69 69 4'f N Cal 0).49 fA C,.) H 40 69 69 69 69 Z Vi N 69 7 0000000000000000000000000000000000 4 000000 M O N O (O OD O 0 N O O n O O 9 0 CD 0 0 0 ti N CD N 1- 0 a 0 A• 0 0 ID O O O M N N O O U) 0 M h 0 O co to O (O O 0 O (O M h N- N V' 0 0 1s 0 N F- O O N (00 t00 M IN CO N O OOD M O CO.N CO.N CO O N a 0 CO M 0 O M IN CO CO N 0) U) 4- O 001 OOD F 4. O U) C) V OD t0 C) M O (O (D CD < < O V' O 1� N 0'I ad H h (O co- '- N V- A 0 ^ (O M OD (D (O I� CD N O CD N M < N N N XX Q N N 69 09 69 69 69 69 69 9 49 69 61 69 9 69 69 69 69 69 H 69 69 69 69 69 69 69 69 M 9 69 69 69 69 69 0 0 4 1 4 1 0 0 0 0 U) 0 0 0 0 0 0 0 0 U) O U) O O IC) O O 10 O 1 1 1 0 0 4 1 0 0 W 0 O N 81 N O M 0 '.t 0 a .- O Cr) N O O 4- N CO V O CD. 0 M 4- O 1- M 0 CO CO O U O O N co O O O N n ad O N U U) O O M O N O O — O D 4 U N co O M U O ix O O M 69 9 co, f9 H 69 N 9 69 69 M 6O 9 0 V O M O H m N M H N CO M 4- 69 M 69 69 CD d O O 69 1 N 6 r M N F- M M 69 69 69 Z 6n y9 69 7 0 0 0 0 0 0 U) U) O O I0 0 0 0 0 0 CD 10 0 0 0 0 0 0 0 0 0 0 CO O UO O O O ti O O O O O O ED 0 0 0 1- 0 0 N 0 0 •- n 0 O O O O O O O O O 0 0 N.- 0 ,-: 0 Oi 0 0 0 O 0 0 0 N V' O O O to co O O f0 O 0 0 0 O O O O O O O (O M M O O O CO F. O O O O CD U) O M 0 O O I` M 0 0 0 0 0 0 R O IO O O O O O O h 0 0 CO O 1 U) O O LC). CO CO M O 01 4- N V' M N O O h N O co m co. 10 U U) U) CO N A' N N H 7 ( U N to N CO O N M n N O N O U (D O 4 O V U 7 r N co n 4- V < q Q 0 N a a O CO CD 4— M 0) R CD N 0- CO 4- 4- 4- CD 4- co G co co N O N W Q N N I- I- M 69 M 69 69 69 69 69 69 69 69 69 9 69 69 9 9 69 69 69 9 co 69 69 69 co 69 69 9 69 69 69 81 69 69 N N C 0 O O U) V' O U) h O 0 U) O U) N O O CO - 0 0 0 0 0 0 0 0 M 0 7 0 U) 0 0 CO 0 W O O O ID V O CD 4 N O t` U) r 1` 0 0. 0 (O O (D 0 0 0 0 0 0 .- 0 .- 0 n U) O E U O 0 0 e{ O O N. N M CO N CO a 0 0 tb M 0 0 0 N O 0 U) CO O M O M U) 0 C 0 0 N 69 69 N 69 69 CD 69 N C- N U) O r co, a N (A O N 1- (O H 69 N 69 69 tD d Q d N 0 fA 00 f9 f9 E9 V6 H M f9 9 H OJ fA M (A C h U) CO- co U) C7 F- O 69 6A 9 69 E 7 f9 fA C O O O O O O N U) O O O O O O O O O O O O O O O O O O O O O O O O O O O / M 'O N 0 0 0 0 O U) O (O 0 0 (DOD) CD O O U) 0 0 .- 0 ? 0 0 0 V; U) N N- 0 0 0 0 C C1)4 to N U) 0 0 U) N O N O 'V O 6 N T O O N (0 O U) O CD M r M N O O O 4 H F- CD (D O N U) CO N M M O CO O N 1� CO N V N CD CO N N CO N 0- M < 1. U) O Cy = J 1 N a CD O CD 8- CO CO N CO M 1- N .1 CO O U) n O (D U) CO M K CD M O M b CO N V) CC 7 CO- CO- 4- CO- M R < N M M N h N- V' co R (O N ,- N to CO .- CO — m N- CO of st G N = 0 ti U) O •'9 CO M N 1- U) M M N CO 4- U) CD 4- 0) O • d d co .Y co OD M A Q Q 69 F- a GF 69 69 FA 69 69 69 69 69 69 fie 69 69 69 V6 69 Vi 69 69 69 69 V! 69 69 69 N 69 69 69 69 Vi 69 69 N 6A /0 Z 0 0 U) O U 0 (1) U U) 0 O 0 U U) U) D O O (1) 0 U) O U O n N O N In O O N 0 iz 7 w N O co. Cu •F O U) U) M (D O ti U) O a O 1- a 1- CO. O (D O O O C- co O O co O to E U t0 U) co O O U) M N M (O O O 4- O O U) 1` N O in M O (O co N R N O 0) rt CD 69 69 U) 69 6A EA 69 CD CO 4- 0 CO M 0 0) CD f9 69 1- 1- M 69 U) 69 t9 CO CO 0 a N < 6' .- 69 69 69 69 N N 69 M 69 U) N 69 N- co 6A () OC OD V- 69 V) Cy t9 69 y 69 C) O F- C- U) co 68 69 t9 69 E 2 69 to 69 E 7 r 0 CO OO O Z — 0 0 - 0 < IN N O D O ci M N N N CD O co O m N O O O m 0 co. N O j ,- co U) N N 0 co O N N '- O ~ C0 CO > a CL t0 > > > > > > > Z Z Z Q > > a Q Q > CO co C0 2 < < 2 CL I Z J J 0 J J J 0 U 0) 0 N U CO F- F- F- W CO O J W W W Q Q < Z W W Z J J 7 W U (O U 0 W W U < W U 0 Z a Z § LL 6 m N F- K F- W Y F- cn F- F- F- Q z = U 1 F- < W p m 2 2 F-to 1 O W ( > U U U z 5 F N z IY 3 w W (0 (0 a cc 17 > (.'J a U O < co co 2 F 2 U a a a a a R 0 m a F F w a a > O U 1 x 2 2 2 O w U 0 = ct o Z F o F --.1 ca 0 W N. 12 2 w 0 W J a a7 W a a p Z Z a v U U1 0 w ¢ 0` co F- ~ ~ W IT LL W 0 V,t H W w z 0OQ ~ O O O p Q W 0 0 0 0 w w f a O O O 0 a 8 O a• J w Q N W W N a a (O w W U ¢ (~i) U ~ d Y W W W Z O OM W Q a 7"-U (n (n z Q Q O 0 0 0 m O Z cw) w z z F- Y < a a n. W m _..<.mss: o 0 O U Q m F- 0 Z Z m Z 0 0 0 W W W Z CO Z ... a Q Z J C7 UI Z W 2 E E E2 5 W W W W 0 < < Z 0) p Z Z O J w a 0 0 0 Z Z > F- W U C> U 1- '5 M cr;a s m Z 0 z ¢ ¢ (a.) m a w 0 0 > > > N W O a > > 7 w z X W a m' ag ag (0 a 0 ca O Q 0 > F- F- w u } � a a 0 U) co cow W F- J O O F- (O (O U 0 C7 C7 C7 a (0 W W O a F- F- F- Cl) (O F- 'a' I, £I-OZ/ZHZ 2/12/2013 11 .D. Bidder I Bid Engineer's Estimate $ 1,813,582.00 100.00% Community Asphalt Corp. $ 1,904,344.00 105.00% APAC Sountheast $ 2,039,569.79 112.46% Average Bid $ 2,164,302.64 119.34% Ajax $ 2,217,757.40 122.29% Wright Construction $ 2,495,539.38 137.60% $2,500,000.00 -�° $2,000,000.00 -," $1,500,000.00 ft Engineer's Estimate $1,000,000.00 a Community Asphalt Corp. gm $500,000.00 , I I I E APAC Sountheast $ f — ■Average Bid y�y� �\Lo J�„re `ale P `,,6,. ,1 Ajax eet Pypr ��o Pie �(Pcy Wright Construction sc ` f � e o Packet Page-942-