Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
#18-7239 (Ferreira Construction Southern Division Company, Inc.)
Colter Coity Ad inistratveSeMces Department 'rOcureme'r ServiJ's Div)sio 1 Dredging of Wiggins and Doctors Passes COLLIER COUNTY BID NO. 18-7239 COLLIER COUNTY, FLORIDA Kristofer Lopez, Procurement Strategist Email: kristoferlopez@colliergov.net Telephone: (239) 252- 8944 FAX: (239) 252- 6593 Design Professional: Aptim Environmental & Infrastructure, Inc. 4, ,) PrtwanentSentor-,7DiAwn t 3327 Tatman Trai!Fast t Nardes,Florida 34112.4 01•:2:x252.`.67•wWM.:nllirrpov mUprocurementservu;es 1 Construction Services Agreement:Revised 06152017 TABLE OF CONTENTS PUBLIC NOTICE 3 PART B - INSTRUCTIONS TO BIDDERS 5 CONSTRUCTION BID 12 BID SCHEDULE 13 MATERIAL MANUFACTURERS 14 LIST OF MAJOR SUBCONTRACTORS 15 STATEMENT OF EXPERIENCE OF BIDDER 17 TRENCH SAFETY ACT 18 IMMIGRATION LAW AFFIDAVIT CERTIFICATION 19 COLLIER COUNTY SOLICITATIONS SUBSTITUTE W-9 20 BID BOND 25 BIDDERS CHECK LIST 26 CONSTRUCTION AGREEMENT 27 EXHIBIT A 1: PUBLIC PAYMENT BOND 34 EXHIBIT A 2: PUBLIC PERFORMANCE BOND 37 EXHIBIT B: INSURANCE REQUIREMENTS 40 EXHIBIT C: RELEASE AND AFFIDAVIT FORM 42 EXHIBIT D: FORM OF CONTRACT APPLICATION FOR PAYMENT 45 EXHIBIT E: CHANGE ORDER 46 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION 47 EXHIBIT G: FINAL PAYMENT CHECKLIST 49 EXHIBIT H: GENERAL TERMS AND CONDITIONS 50 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS 77 EXHIBIT J: TECHNICAL SPECIFICATIONS 78 EXHIBIT K: PERMITS 79 EXHIBIT L: STANDARD DETAILS 80 EXHIBIT M: PLANS AND SPECIFICATIONS 81 EXHIBIT N: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT 82 2 Construction Services Agreement:Revised 06152017 Ccs ,er Co rnty Administatve Sen4ces Department Proe uremenl Serm..es C P,won PUBLIC NOTICE INVITATION TO BID Dredging of Wiggins and Doctors Passes COUNTY BID NO. 18-7239 Sealed bids for the construction of Dredging of Wiggins and Doctors Passes will be received electronically until 2:30 P.M. LOCAL TIME, on the 1st day of December, 2017 on the County's on-line bidding system: www.colliergov.net/bid. All bids will be publicly opened and read aloud. Any bids received after the time and date specified will not be accepted and shall be returned unopened to the Bidder. The anticipated project budget is: $2,125,000. A non-mandatory pre-bid conference shall be held at the Procurement Services Division, Conference Room A, at 2:00 p.m. LOCAL TIME on the 8th day of November, 2017, at which time all prospective Bidders may have questions answered regarding the Bidding Documents for this Project. Bids shall be received on line by the Bid Date of December 1, 2017 @ 2:30 P.M. No bid shall be considered unless it is made on unaltered Bid forms which are included in the Bidding Documents. One contract will be awarded for all Work. Bidding Documents may be examined on the Collier County Procurement Services Division Online Bidding System website: www.colliergov.net/bid. Copies of the Bidding Documents may be obtained only from the denoted website. Bidding Documents obtained from sources other than the Collier County Procurement Services Division website may not be accurate or current. Each bid shall be accompanied by a certified or cashier's check or a Bid Bond in an amount not less than five percent (5%) of the total Bid to be retained as liquidated damages in the event the Successful Bidder fails to execute the Agreement and file the required bonds and insurance within ten (10) calendar days after the receipt of the Notice of Award. The Successful Bidder acknowledges and agrees that it shall execute the Agreement in the form attached hereto and incorporated herein. The Successful Bidder shall be required to furnish the necessary Payment and Performance Bonds, as prescribed in the General Conditions of the Contract Documents. All Bid Bonds, Payment and Performance Bonds, Insurance Contracts and Certificates of Insurance shall be either executed by or countersigned by a licensed resident agent of the surety or insurance company having its place of business in the State of Florida. Further,the said surety or insurance company shall be duly licensed and qualified to do business in the State of Florida. Attorneys-in-fact that sign Bid Bonds or Payment and Performance Bonds must file with each bond a certified and effective dated copy of their Power of Attorney. In order to perform public work, the Successful Bidder shall, as applicable, hold or obtain such contractor's and business licenses, certifications and registrations as required by State statutes and County ordinances. Before a contract will be awarded for the Work contemplated herein, the Owner shall conduct such investigations as it deems necessary to determine the performance record and ability of the 3 Construction Services Agreement:Revised 06152017 apparent low Bidder to perform the size and type of work specified in the Bidding Documents. Upon request, the Bidder shall submit such information as deemed necessary by the Owner to evaluate the Bidder's qualifications. The Successful Bidder shall be required to finally complete all Work within 125 (125) calendar days from and after the Commencement Date specified in the Notice to Proceed. The Owner reserves the right to reject all Bids or any Bid not conforming to the intent and purpose of thwe Bidding, Documents,extend beyond one hundred`twenty (120) daysard of the tfor a from theriod of time which, b d opening date however, shall not e t Y without the consent of the Successful Bidder. Dated this 27 day of October, 2017. BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA BY: /s/ Edward F. Coyman, Jr. Director, Procurement Services Division 4 Construction Services Agreement:Revised 06152017 PART B-INSTRUCTIONS TO BIDDERS Section 1. Definitions 1.1 The term "Owner' used herein refers to the Board of County Commissioners, or its duly authorized representative. 1.2 The term "Project Manager" used herein refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. 1.3 The term "Design Professional" refers to the licensed professional engineer or architect who is in privity with the Owner for the purpose of designing and/or monitoring the construction of the project. At the Owner's discretion, any or all duties of the Design Professional referenced in the Contract Documents may be assumed at any time by the Project Manager on behalf of the Owner. Conversely, at the Owner's discretion the Project Manager may formally assign any of his/her duties specified in the Contract Documents to the Design Professional. 1.4 The term "Bidder' used herein means one who submits a bid directly to the Owner in response to this solicitation. 1.5 The term "Successful Bidder" means the lowest, qualified, responsible and responsive Bidder who is awarded the contract by the Board of County Commissioners, on the basis of the Owner's evaluation. 1.6 The term "Bidding Documents" includes the Legal Advertisement, these Instructions to Bidders, the Bid Schedule and the Contract Documents as defined in the Agreement. 1.7 The term "Bid" shall mean a completed Bid Schedule, bound in the Bidding Documents, properly signed, providing the Owner a proposed cost for providing the services required in the Bidding Documents. Section 2. Preparation of Bids 2.1 The Bids must be submitted on the standard form herein furnished by the Owner(pages 15 - 29 as bound in these Bidding Documents). By submitting a Bid, Bidder acknowledges and agrees that it shall execute the Agreement in the form attached hereto and incorporated herein. The Bidder shall complete the Bid and shall sign the Bid correctly. The Bid may be rejected if it contains any omission, alteration of form, conditional bid or irregularities of any kind. Bids must be submitted on www.colliergov.net/bid Section 3. Bid Deposit Requirements 3.1 No Bid shall be considered or accepted unless at the time of Bid filing the same shall be accompanied by a cashier's check, a cash bond posted with the County Clerk, a certified check payable to Owner on some bank or trust company located in the State of Florida insured by the Federal Deposit Insurance Corporation, or Bid Bond, in an amount not less than 5% of the bidder's maximum possible award (base bid plus all add alternates) (collectively referred to herein as the "Bid Deposit"). The Bid Deposit shall be retained by Owner as liquidated damages if the Successful Bidder fails to execute and deliver to Owner the unaltered Agreement, or fails to deliver the required Performance and Payment Bonds or Certificates of Insurance, all within ten (10calendar receipt the State Award. Bonds l be eby corporate surety licensed underthe laws of the of Floridaloridato execute such bonds, with 5 Construction Services Agreement:Revised 06152017 conditions that the surety will, upon demand, forthwith make payment to Owner upon said bond. Bid Deposits of the three(3) lowest Bidders shall be held until the Agreement has been executed by the Successful Bidder and same has been delivered to Owner together with the required bonds and insurance, after which all three (3) Bid Deposits shall be returned to the respective Bidders. All other Bid Deposits shall be released within ten (10)working days of the Bid Opening. No Bid including alternates, shall be withdrawn within one hundred and twenty(120)days after the public opening thereof. If a Bid is not accepted within said time period it shall be deemed rejected and the Bid Deposit shall be returned to Bidder. In the event that the Owner awards the contract prior to the expiration of the one hundred twenty(120)day period without selecting any or all alternates, the Owner shall retain the right to subsequently award to the Successful Bidder said alternates at a later time but no later than one hundred twenty (120) days from opening, unless otherwise agreed by the Procurement Director and the Successful Bidder. 3.2 The Successful Bidder shall execute two(2) copies of the Agreement in the form attached and deliver same to Owner within the time period noted above. The Owner shall execute all copies and return one fully executed copy of the Agreement to Successful Bidder within thirty(30) working days after receipt of the executed Agreement from Successful Bidder unless any governmental agency having funding control over the Project requires additional time, in which event the Owner shall have such additional time to execute the Agreement as may be reasonably necessary. Section 4. Right to Reject Bids 4.1 The Owner reserves the right to reject any and all Bids or to waive informalities and negotiate with the apparent lowest, qualified Bidder to such extent as may be necessary for budgetary reasons. Section 5. Signing of Bids 5.1 Bids submitted by a corporation must be executed in the corporate name by the president, a vice president, or duly authorized representative. The corporate address and state of incorporation must be shown below the signature. 5.2 Bids by a partnership must be executed in the partnership name and signed by a general partner whose title must appear under the signature and the official address of the partnership must be shown below said signature. 5.3 If Bidder is an individual, his or her signature shall be inscribed. 5.4 If signature is by an agent or other than an officer of corporation or general partner of partnership, a properly notarized power of attorney must be submitted with the Bid. 5.5 All Bids shall have names typed or printed below all signatures. 5.6 All Bids shall state the Bidder's contractor license number. 5.7 Failure to follow the provisions of this section shall be grounds for rejecting the Bid as irregular or unauthorized. Section 6. Withdrawal of Bids Any Bid may be withdrawn at any time prior to the hour fixed in the Legal Advertisement for the opening of Bids, provided that the withdrawal is requested in writing, properly executed by the 6 Construction Services Agreement:Revised 06152017 Bidder and received by Owner prior to Bid Opening. The withdrawal of a Bid will not prejudice the right of a Bidder to file a new Bid prior to the time specified for Bid opening. Section 7. Late Bids No Bid shall be accepted that fails to be submitted prior to the time specified in the Legal Advertisement. Section 8. Interpretation of Contract Documents 8.1 No interpretation of the meaning of the plans, specifications or other Bidding Documents shall be made to a Bidder orally. Any such oral or other interpretations or clarifications shall be without legal effect. All requests for interpretations or clarifications shall be in writing and addressed on the County's Online Bidding System to be given consideration. All such requests for interpretations or clarification must be received as directed in the Online Bidding System instructions and prior to the Bid opening date. Any and all such interpretations and supplemental instructions shall be in the form of written addendum which, if issued via the Online Bidding System at their respective email addresses furnished for such purposes no later than three (3) working days prior to the date fixed for the opening of Bids. Such written addenda shall be binding on Bidder and shall become a part of the Bidding Documents. 8.2 It shall be the resposu d ity andf it shalleach aicdknowledge same der to ascertain, pnior its Bidubmitting its Bid, that it has received all addenda is ed As noted in the Legal Advertisement, attendance by all bidders at the Pre-Bid Conference is non-mandatory. Section 9. Examination of Site and Contract Documents 9.1 By executing and submitting its Bid, each Bidder certifies that it has: a. Examined all Bidding Documents thoroughly; b. Visited the site to become familiar with local conditions that may in any manner affect performance of the Work; c. Become familiar with all f deWorst and and local laws, ordinances, rules, and regulations affecting performance of d. Correlated all of its observations with the requirements of the Bidding documents. at No plea of ignorance of conditions or difficultiesothat may exist or u suant to these Bidding g Documents tions or difficulties s athesu t of ay be encountered in the execution of the p failure to make the necessary examinations and investigations shall be accepted as an excuse for any failure or omission on the part of the Successful Bidder, nor shall they be accepted as a basis for any claims whatsoever for extra compensation or for an extension of time. 9.2 The Owner will make copies of surveys and reports performed in the junction Owner doeswith this Project available to any Bidder requesting them at cost; provided, however, not warrant or Before representub to any its B each Bidder shther the leteness or accuracy of any such surveys and all, at its own expense, make such additional reports. Before submitting its Bid, surveys and investigations as may be necessary to determine its Bid price for the performance of 7 Construction Services Agreement:Revised 06152017 the Work within the terms of the Bidding Documents. This provision shall be subject to Section 2.3 of the General Conditions to the Agreement. Section 10. Material Requirements It is the intention of these Bidding Documents to identify standard materials. When space is provided on the Bid Schedule, Bidders shall specify the materials which they propose to use in the Project. The Owner may declare any Bid non-responsive or irregular if such materials are not specifically named by Bidder. Section 11. Bid Quantities 11.1 Quantities given in the Bid Schedule,while estimated from the best information available, are approximate only. Payment for unit price items shall be based on the actual number of units installed for the Work. Bids shall be compared on the basis of number of units stated in the Bid Schedule as set forth in the Bidding Documents. Said unit prices shall be multiplied by the bid quantities for the total Bid price. Any Bid not conforming to this requirement may be rejected. Special attention to all Bidders is called to this provision, because if conditions make it necessary or prudent to revise the unit quantities,the unit prices will be fixed for such increased or decreased quantities. Compensation for such additive or subtractive changes in the quantities shall be limited to the unit prices in the Bid. Subsequent to the issuance of a notice to proceed,the Project Manager and the Successful Bidder shall have the discretion to re-negotiate any unit price(s) where the actual quantity varies by more than twenty-five percent(25%) from the estimate at the time of bid. 11.2 Alternate Bid Pricing: In the event that alternate pricing is requested, it is an expressed requirement of the bid invitation to provide pricing for all alternates as listed. The omission of a response or a no-bid or lack of a submitted price may be the basis for the rejection of the submitted bid response. Section 12. Award of Contract 12.1 Any prospective bidder who desires to protest any aspect(s) or provision(s) of the bid invitation (including the form of the bid documents or bid procedures) shall file their protest with the Procurement Director prior to the time of the bid opening strictly in accordance with Owner's then current procurement ordinance and policies. 12.2 Statement of Award: The Award of Contract shall be issued to the lowest, responsive and responsible Bidder determined by the base bid, and any, or all, selected alternates, and the Owner's investigations of the Bidder. In determining the lowest, responsive and responsible bidder, the Owner shall consider the capability of the Bidder to perform the contract in a timely and responsible manner. When the contract is awarded by Owner,such award shall be evidenced by a written Notice of Award, signed by a Procurement professional of the Owner's Procurement Services Division or his odd designeand the delivered to the intended awardee or mailed to awardee at the business 12.3 Award recommendations will be posted on the Procurement Services Division Web Site. Award of Contract will be made by the Board of County Commissioners in public session. Any actual or prospective bidder who desires to formally protest the recommended contract award must file a notice of intent to protest with the Procurement Director within two (2) calendar days (excluding weekends and holidays) of the date recommended posted. Upon filing of said notice,the protesting party will have five (5) days to a formal protest, said protest 8 Construction Services Agreement:Revised 06152017 to strictly comply with Owner's then current procurement ordinance and policies. A copy of the procurement ordinance is available at: http://www.colliergov.net/Index.aspx?page=762 12.4 For Bidders who may wish to receive copies of Bids after the Bid opening, The Owner reserves the right to recover all costs associated with the printing and distribution of such copies. 12.5 Certificate of Authority to Conduct Business in the State of Florida (FL Statute 607.1501) In order to be considered for award,firms must be registered with the Florida Department of State Divisions of Corporations in accordance with the requirements of Florida Statute 607.1501 and provide a certificate of authority (www.sunbiz.orq/search.html) prior to execution of a contract. A copy of the document may be submitted with the solicitation response and the document number shall be identified. Firms who do not provide the certificate of authority at the time of response shall be required to provide same within five (5) days upon notification of selection for award. If the firm cannot provide the document within the referenced timeframe, the County reserves the right to award to another firm. Section 13. Sales Tax 13.1 The Successful Bidder acknowledges and agrees that Owner may utilize a sales tax savings program and the Successful Bidder agrees to fully comply, at no additional cost to Owner, with such sales tax savings program implemented by the Owner as set forth in the Agreement and in accordance with Owner's policies and procedures. Section 14. Exclusion of County Permits in Bid Prices 14.1 To ensure compliance with Section 218.80, F.S., otherwise known as "The Publicfc d Bed Disclosure Act", Collier County will pay the Contractor for all Collier County permits s applicable to the Project, including license fees, permit fees, impact fees or inspection fees applicable to this Work through an internal budget transfer(s). Hence, bidders shall not include these permit/fee amounts in their bid offer. However, the Successful Bidder shall retain the responsibility to initiate and complete all necessary and appropriate actions to obtain the required permits other than payment for the items identified in this section. Owner will not be obligated to pay for any permits obtained by Subcontractors. 14.2 The Successful Bidder shall be responsible for procuring and paying for all necessary permits not issued by Collier County pursuant to the prosecution of the work. Section 15. Use of Subcontractors 15.1 To ensure the Work contemplated by the Contract Documents is performed in a professional and timely manner, all Subcontractors performing any portion of the work on this Project shall be"qualified" as defined in Collier County Ordinance 2017-08, as amended,meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements and has the integrity and reliability to assure good faith performance. A Subcontractor's disqualification from nsthe O other public contracting within the past twelve mnthsshallbe onideedbythe Ownerwhedetemingwhethere Subcontractors are "qualified." 9 Construction Services Agreement Revised 06152017 15.2 The Owner may consider the past performance and capability of a Subcontractor when evaluating the ability, capacity and skill of the Bidder and its ability to perform the Agreement within the time required. Owner reserves the right to disqualify a Bidder who includes Subcontractors in its bid offer which are not"qualified" or who do not meet the legal requirements applicable to and necessitated by this Agreement. 15.3 The Owner may reject all bids proposing the use of any subcontractors who have been disqualified from submitting bids to the Owner,disqualified or de-certified for bidding purposes by any public contracting entity, or who has exhibited an inability to perform through any other means. 15.4 Notwithstanding anything in the Contract Documents to the contrary, the Bidder shall identify the subcontractor(s) it intends to use for the categories of work as set forth in the List of Subcontracts attached hereto, said list to be submitted with its bid. Bidders acknowledge and agree that the subcontractors identified on the list is not a complete list of the subcontractors to be used on the Project, but rather only the major subcontractors for each category of Work as established by Owner. Bidders further acknowledge that once there is an Award of Contract, the SuccessfulBidder rasubjectw and app subcontractors it intends to use onthe ProJect. Once approved by Owner, nosubcontractor shall be removed or replaced without Owner's prior written approval. Section 16. Prohibition of Gifts No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2003-53, as amended, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and/or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual and/or firm for cause. Section 17. Lobb in All firms are hereby placed on NOTICE that the Board of County Commissioners does not wish to be lobbied, either individually or collectively about a project for which a firm has submitted a response. Firms and their agents are not to contact members of the County Commission for such purposes as meeting or introduction, luncheons, dinners, etc. During the process, from solicitation closing to final Board approval, no firm or their agent shall contact any other employee of Collier County in reference to this solicitation, or the vendor's response, with the exception of the Procurement Director or his designee(s). Failure to abide by this provision may serve as grounds for disqualification for award of this contract to the firm. Section 18. Public Entity Crimes it is in By its submitting S Bid, Bidderacknowledges Iofdtg asFlon'da Statutes which agrees to and read as follows:compliance with the terms of "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may 10 Construction Services Agreement:Revised 06152017 not submit bids, proposals, or replies on leases of real property to a public entity'; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." 11 Construction Services Agreement:Revised 06152017 CONSTRUCTION BID BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA Dredging of Wiggins and Doctors Passes BID NO. 18'7239 Full Name of Bidder Ferreira Construction Southern Division Co.. Inc, Main Business Address 31 Tannery Road, BranChbu[g, NJ 08876 Place of Business T1203, Kanner HYVy., Stuart, FL349B7 Telephone No. 772-286-5123 Fax No. 772-286-5139 State Contractor's License # CGC1509418 State of Florida Certificate of Authority Document Number F04000001981 Federal Tax Identification Number 22-3334957 DUNS # 031760697 CCR# --' Cage Code 1(]5K9 To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA (hereinafter called the Owner) The undersigned, as Bidder declares that the only person or parties interested in this Bid as principals are those named henain, that this Bid is submitted without collusion with any other pereon, firm or corporation; that it has carefully examined the location of the proposed VVnrk, the proposed form of Agreement and all other Contract Documents and Bonds, and the Contract Drawings and Specifications. Bidder pvoposos, and agrees if this Bid is aCoSpted. Bidder will execute the Agreement included in the Bidding Donuments, to provide all necessary mauhinery, hoo|s, apparatus and other means of omnstructimn, including utility and transportation services necessary to do all the Work, and furnish all the materials and equipment specified or referred to in the Contract Documents in the manner and time herein prescribed and according to the requirements of the Owner as therein set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the COntract, and to do all other things required of the Contractor by the Contract Documents, and that it will take full payment the sums set forth in the following Bid Schedule: Unit prices shall be provided in no more than two decimal points, and in the case where further decimal points are inadvertently prmvided, rounding to two decimal points will be conducted by Procurement Services Division staff. 12 Construction Services Agreement Revised 06152011 /fie 11",# 4 10 z +a7 UJ z a Y 0 Q usot 0-3 n CI a wr Z 4 z Oz vs r 'Q al 1d3 U) Ca a re a.> 0 Lu z e4 G8. n I 0 n 0 4(n z j`'� rt ILI ti)C3 4 ' .-i. V co 17)0 8 _a mC1 z a.tic a. 0 L 1- zz 0 No LL z co co 0 tri CJ O.4 It h- -a vs ILI Cr ;13 Oz) 0 'craas _ 0� Lu 0 000 o, < a, L p ..1 > At ....1 In U) • L1 „ c --Q ti) zo W 6) k 5LLI• 0 otv tc, Lo W.: o sznoG •4 _F-z LLI Detail by Entity Name FLORIDA DEPARTMENT of STATE DIVISION OF CORPORATIONS DIVISION of 5" br COOR iTIO an official Stare of Florida website Department of State / Division of Corporations / Search Records / Detail By Document Number / Previous On List Next On List Return to List ferreira construction southern division Saarch No Events No Name History Detail by Entity Name Foreign Profit Corporation FERREIRA CONSTRUCTION SOUTHERN DIVISION CO. INC. Cross Reference Name FERREIRA CONSTRUCTION CO. INC. Filing Information Document Number F04000001981 FEI/EIN Number 22-3334957 Date Filed 04/09/2004 State NJ Status ACTIVE Principal Address 31 TANNERY ROAD BRANCHBURG, NJ 08876 Changed: 01/09/2007 Mailing Address 31 TANNERY ROAD BRANCHBURG, NJ 08876 Changed: 01/09/2007 Registered Agent Name & Address FERREIRA, NELSON 600 OCEAN DRIVE APT. #7A JUNO BEACH, FL 33408 Officer/Director Detail http://search.sunbiz,org/...construction%20southern%20division&IistNameOrder=FERREIRACONSTRUCTIONSOUTHERNDI%20F040000019810[12/19/2017 8:37:51 AM] Detail by Entity Name Name & Address Title PRES FERREIRA, NELSON 896 OLD CHESTER GLADSTONE ROAD FAR HILLS, NJ 07931 Title VP GARCIA, DICTINIO 17 FRANCIS DRIVE HILLSBOROUGH, NJ 08844 Title SEC PACHECO, LOU 86 VOLLERS DR. BRANCHBURG, NJ 08876 Title VP DELPOME, BRIAN 124 PATRICK AVE EMERSON, NJ 07630 Title VP GROARK, THOMAS J 15 RIDGECREST NORTH SCARSDALE, NY 10583 Title VP VLIET, NANCY 19 Thomas Rd Glen Gardner, NJ 08826 Title Sr.Vice President/ CFO Killian, Jerome 30 Horseshoe Dr Hillsborough, NJ 08844 Title VP CIABATTARI, JOHN 5271 SW WINDWARD WAY http://search.sunbiz.org/...construction%20southem%20division&IistNameOrder—FERREIRACONSTRUCTIONSOUTHERNDI%20F04000001981O[12/19/2017 8:37:51 AM: Detail by Entity Name PALM CITY, FL 34990 Title VP GARCIA, DANNY 9804 SW 161 PLACE MIAMI, FL 33196 Annual Reports Report Year Filed Date 2015 01/06/2015 2016 01/13/2016 2017 01/12/2017 Document Images 01/12/2017 -- ANNUAL REPORT View image in PDF format 01/13/2016 -- ANNUAL REPORT View image in PDF format 01/06/2015 -- ANNUAL REPORT View image in PDF format 01/08/2014 -- ANNUAL REPORT View image in PDF format 01/04/2013 -- ANNUAL REPORT View image in PDF format 01/03/2012 -- ANNUAL REPORT View image in PDF format 01/05/2011 --ANNUAL REPORT View image in PDF format 02/25/2010 -- ANNUAL REPORT View image in PDF format 01/05/2010 -- ANNUAL REPORT View image in PDF format 01/09/2009 -- ANNUAL REPORT View image in PDF format 01/02/2008 -- ANNUAL REPORT View image in PDF format 01/I 007 -- ANNUAL `EPSRT View image in PDF format 03/07/2006 -- ANNUAL REPORT View image in PDF format 01/10/2005 -- ANNUAL REPORT View image in PDF format 04/09/2004 -- Foreign Profit View image in PDF format Iferreira construction southern division'J Previous On List Next On List Return to List I t No Events No Name History Florida Department of State,Division of Corporations nnncfructinn%20southern%20division&listNameOrdet=FERREIRACONSTRUCTIONSOUTHERNDI%20F040000019810[12/19/2017 8:37:51 AN BID SCHEDULE Dredging of Wiggins and Doctors Passes Bid No. 18-7239 "Also attached,hereto,following this page" 13 Construction Services Agreement:Revised 06152017 2017 Wiggins and Doctors Pass Maintence Dredging Collier County,Florida Bid Form Item Description Unit Contract Unit Price Total Quantity Common Tasks 1 Mobilization/Danobilization Lump Sum 1 $1,096,813.50 $1,096,813.50 2 Environmental&Sediment QA/QC Compliance Lump Sum 1 $13,050.00 $13,050.00 3 Laboratory Sand Analysis Each 20 $63.25 $1,265.00 Wiggins Pass Dredging and Disposal 4 Ebb Channel Sta. 15+00 to-2+00 C.Y. 68,230 $5.20 $354,796.00 5 Interior Channel Sta.-2+00 to C-23 and C-29 to C-31 C.Y. 30,720 $7.40 $227,328.00 6 Construction Surveys-Wiggins Pass Lump Sum 1 $73,700.00 $73,700.00 7 Relocation of Channel Markers Each 12 $1,015.00 $12,180.00 Doctor Pass Dredging and Dispaol 8 Settling Basin&Entrance Channel EC 00+00 to EC 15+70 C.Y. 23,050 $8.20 $189,010.00 9 Turning Basin and Interior Channels EC 15+70 to E4+85, C.Y. 7,250 $10.35 $75,037.50 W8+12 and E17+51 10 Construction Surveys-Doctors Pass Lump Sum 1 $47,700.00 $47,700.00 11 Construction Access Restoration Lump Sum 1 $8,100.00 $8,100.00 Total $2,098,980.00 MATERIAL MANUFACTURERS THIS FORM MUST BE COMPLETED OR BID SHALL BE DEEMED NON-RESPONSIVE AU Bidders shall confirm by signature that they will provide the manufacturers and materials outlined in this Bid specifications, including compliance with Florida Statute 255.20 to provide |urnber. timber and other forest products produced and manufactured in the State of Florida as long as the price, fitness and quality are equal. Exceptions (when equals are acceptable)may be requested by completing the Material Manufacturer Exception List below. If an exception for a manufacturer and/or material is proposed and listed below and is not approved by Engineer/Project Manager, Bidder shall furnish the manufacturer named in the specification. Acceptance of this form does not constitute acceptance of material proposed on this list. Comp|otaandsignuenhonAOR B. Section A(Acceptance of all manufactures and materials in Bid specifications) On behalf of my firm, I confirm that we will use all manufacturers and materials as specifically outlined in the Bid specifications. Company: Ferreira Construction Soutrn Division Co., Inc. Signature: {''�+�z�^ Date: 12/1/17 Joh iabattari, Vice President Section B (Exception requested to Bid specifications manufacturers and materials) EXCEPTION MATERIAL EXCEPTION MANUFACTURER 1. 2. 3. 4. 5. Please insert additional pages as necessary. Company: Signature: Date w Construction Services Agreement:Revised 06152017 **********PAGE INTENTIONALLY LEFT BLANK********** 15 Construction Services Agreement:Revised 06152017 LIST OF MAJOR SUTORS THIS LIST MUST BE COMPLETED OR BID MAY BE DEEMED NON-RESPONSIVE The undersigned states that the following is a list of the proposed subcontractors for the major categories outlined in the requirements of the Bid specifications. The undersigned acknowledges its vresponsibility for ensuring that the Subcontractors for the major m�ned |n [)pdinance2O17-08mndInstructions ��ection15of nm to Bidders) and eet all legal (asrequirements applicable to and necessitated by the C�-''tractDocuments, including, but not limited toproper licenses, certifications, registrations and The[. Owner reservesthe righttodioqua|ihany Bidder who includes non- / insurance coverage. n ' compliant or non-qualified Subcontractors in its bid offer. Further, the Owner may direct the Successful Bidder bznammme�ep|amaany Subcontractor, at no cost toJwnmr. which is found hohenon-compan withthis req non-compliantuirement either before or after the issuance of the Award of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned acknowledges and agrees that promptly after the Award of Contract, and in accordance with the requirements of the Contract Documents, the Successful Bidder shall identify all Subco ntrao1orn it intends to use on the Project. The undersigned further agrees that all Subcontractors must e qualified as noted above. Major Category of Work Subcontractor and Address 1. Electrical None 2. Mechanical None 3. Plumbing None 4. Site Work None 5. Identify other None subcontractors that represent more than 10% of price or that affect the critical path of the schedule Company: Ferreira Construction Southern Division Co„ Inc. Signature: _ ~^^ Date: 1���12/1/177 , '.- John C . Vk��PReS�HD 16 Construction ServiceAgreement:Revised 061520 7 STATEMENT OF EXPERIENCE OF BIDDER The Bidder is required to state below what work of similar magnitude completed within the last five (5) years is a judge of its experience, skill and business standing and of its ability to conduct the work as completely and as rapidly as required under the terms of the Agreement. Project and Location Reference (include phone#or email address) 1. Band Pass Maintenance Stephen Boutelle 239-533-8128 Sanibel-Captiva Islands, Lee County, FL sboutelleOjeegov.com Bathtub Beach/Sailfish Point Beach Kathy Fitzpatrick 772-288-5429 2. Construction Project, Stuart, FL kfitzpat@martin.fl.us Logistec Berth Dredging (2016&2017) David Proctor 912-264-4044 X238 3. Brunswick,GA dproctor@logistec.com Sailfish Point Annual Maintenance Dredging E J. Ewing 772-225-1001 4. Sailfish Point, Stuart, FL ewing@sailfishpoint.com Jupiter Inlet Sand Trap Dredging Michael Grella 561-746-2223 5. Jupiter, FL mgrella@jupiterinletdistrict.org 6. Company: Ferreira Construction Southern Division Co., Inc. Signature: Air - Date: 12/1/17 John Ciab ri, Vice President 17 Construction Services Agreement:Revised 06152017 TRENCH SAFETY ACT Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of Florida) effective October 1, 1990. The Bidder further identifies the cost to be summarized below: Trench Safety Units of Unit Unit Extended Measure Measure (C)uanUty) Cost Cost (DesuripUon) (LF.GY> 1. N/A 2. 3. 4. 5, TOTAL$ NIA Failure to complete the above may result in the Bid being declared non-responsive. Company: Ferreira Consy4ction Sottthern,Division Co„ Inc. Signature: / ' ^•~ � wWp---- Date: 12/1/17 John,Johntabattari Vice President / 18 Construction ServiceAgreement'Revised 061520 r Colter County Administrative Services Department P,oarremeni Semors ccs Dr:.srcx, Immigration Law Affidavit Certification Solicitation: 18-7239 Dredging of Wiggins and Doctors Passes This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with formal Invitations to Bid (ITB's)and Request for Proposals(RFP)submittals. Further,Vendors/Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the vendor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Failure to include this Affidavit and acceptable evidence of enrollment in the E-Verify program, may deem the Vendor 1 Bidder's proposal as non-responsive. Collier County will not intentionally award County contracts to any vendor who knowingly employs unauthorized alien workers, constituting a violation of the employment provision contained in 8 U.S.C. Section 1324 a(e)Section 274A(e) of the Immigration and Nationality Act("INA"). Collier County may consider the employment by any vendor of unauthorized aliens a violation of Section 274A(e) of the INA. Such Violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be grounds for unilateral termination of the contract by Collier County. Vendor attests that they are fully compliant with all applicable immigration laws(specifically to the 1986 Immigration Act and subsequent Amendment(s))and agrees to comply with the provisions of the Memorandum of Understanding with E- Verify and to provide proof of enrollment in The Employment Eligibility Verification System (E-Verify), operated by the Department of Homeland Security in partnership with the Social Security Administration at the time of submission of the Vendor's/Bidder's proposal. Company Name Ferreira Construction Southern Division Co., Inc. Print Name John Ciabattari Title Vice President ./ Signature Date 1211/17 State of Florida County of Martin The foregoing instrument was signed and acknowledged before me this 1st day of December , 20 17 , by John Ciabattari (print or type name)who has produced personally known _ (type of identification and number)as identification. Nq y ublic Signature ,�; JOB J.IRELAND 1 MY COMMISSION#GG 416790 Job J. Ireland 1.6 �"ew:cc EXPIRES:August 10,2020 Printed Name of Notary Public °",,,gp� Borded7»n'Nom'PubicUnderwriteis GG016798/8(10/20 Notary Commission Number/Expiration The signee of this Affidavit guarantees, as evidenced by the sworn affidavit required herein, the truth and accuracy of this affidavit to interrogatories hereinafter made. 19 Construction Services Agreement:Revised 06152017 - Su xa s cr VeriFyS Company ID Number: 798869 THE E-VERIFY MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS ARTICLE I PURPOSE AND AUTHORITY The parties to this agreement are the Department of Homeland Security (DHS) and the Ferreira Construction Co.,lnc. (Employer). The purpose of this agreement is to set forth terms and conditions which the Employer will follow while participating in E-Verify. E-Verify is a program that electronically confirms an employee's eligibility to work in the United States after completion of Form 1-9, Employment Eligibility Verification (Form 1-9). This Memorandum of Understanding (MOU) explains certain features of the E-Verify program and describes specific responsibilities of the Employer, the Social Security Administration (SSA), and DHS. Authority for the E-Verify program is found in Title IV, Subtitle A, of the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Pub. L. 104-208, 110 Stat. 3009, as amended (8 U.S.C. § 1324a note). The Federal Acquisition Regulation (FAR) Subpart 22.18,"Employment Eligibility Verification" and Executive Order 12989, as amended, provide authority for Federal contractors and subcontractors (Federal contractor)to use E-Verify to verify the employment eligibility of certain employees working on Federal contracts. ARTICLE II RESPONSIBILITIES A. RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the following notices supplied by DHS in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system: a. Notice of E-Verify Participation b. Notice of Right to Work 2. The Employer agrees to provide to the SSA and DHS the names, titles, addresses, and telephone numbers of the Employer representatives to be contacted about E-Verify. The Employer also agrees to keep such information current by providing updated information to SSA and DHS whenever the representatives' contact information changes. 3. The Employer agrees to grant E-Verify access only to current employees who need E-Verify access. Employers must promptly terminate an employee's E-Verify access if the employer is separated from the company or no longer needs access to E-Verify. Page 1 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 Ever",Ify Company ID Number: 798869 4. The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual. 5. The Employer agrees that any Employer Representative who will create E-Verify cases will complete the E-Verify Tutorial before that individual creates any cases. a. The Employer agrees that all Employer representatives will take the refresher tutorials when prompted by E-Verify in order to continue using E-Verify. Failure to complete a refresher tutorial will prevent the Employer Representative from continued use of E-Verify. 6. The Employer agrees to comply with current Form 1-9 procedures, with two exceptions: a. If an employee presents a "List B" identity document, the Employer agrees to only accept"List B" documents that contain a photo. (List B documents identified in 8 C.F.R. § 274a.2(b)(1)(B)) can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons, the Employer should contact E-Verify at 888-464-4218. b. If an employee presents a DHS Form 1-551 (Permanent Resident Card), Form 1-766 (Employment Authorization Document), or U.S. Passport or Passport Card to complete Form 1-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employee's Form 1-9. The Employer will use the photocopy to verify the photo and to assist DHS with its review of photo mismatches that employees contest. DHS may in the future designate other documents that activate the photo screening tool. Note: Subject only to the exceptions noted previously in this paragraph,employees still retain the right to present any List A, or List B and List C, document(s) to complete the Form 1-9. 7. The Employer agrees to record the case verification number on the employee's Form 1-9 or to print the screen containing the case verification number and attach it to the employee's Form 1-9. 8. The Employer agrees that, although it participates in E-Verify, the Employer has a responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 274B of the INA with respect to Form 1-9 procedures. a. The following modified requirements are the only exceptions to an Employer's obligation to not employ unauthorized workers and comply with the anti-discrimination provision of the INA: (1) List B identity documents must have photos, as described in paragraph 6 above; (2)When an Employer confirms the identity and employment eligibility of newly hired employee using E-Verify procedures, the Employer establishes a rebuttable presumption that it has not violated section 274A(a)(1)(A) of the Immigration and Nationality Act (INA)with respect to the hiring of that employee; (3) If the Employer receives a final nonconfirmation for an employee, but continues to employ that person, the Employer must notify DHS and the Employer is subject to a civil money penalty between $550 and $1,100 for each failure to notify DHS of continued employment following a final nonconfirmation; (4) If the Employer continues to employ an employee after receiving a final nonconfirmation, then the Employer is subject to a rebuttable presumption that it has knowingly Page 2 of 17 E-Verify MOU for Employers i Revision Date 06/01/13 �x S }l vAl 1Ver Company ID Number: 798869 employed an unauthorized alien in violation of section 274A(a)(1)(A); and (5) no E-Verify participant is civilly or criminally liable under any law for any action taken in good faith based on information provided through the E-Verify. b. DHS reserves the right to conduct Form 1-9 compliance inspections, as well as any other enforcement or compliance activity authorized by law, including site visits, to ensure proper use of E-Verify. 9. The Employer is strictly prohibited from creating an E-Verify case before the employee has been hired, meaning that a firm offer of employment was extended and accepted and Form 1-9 was completed. The Employer agrees to create an E-Verify case for new employees within three Employer business days after each employee has been hired (after both Sections 1 and 2 of Form 1-9 have been completed), and to complete as many steps of the E-Verify process as are necessary according to the E-Verify User Manual. If E-Verify is temporarily unavailable,the three-day time period will be extended until it is again operational in order to accommodate the Employer's attempting, in good faith, to make inquiries during the period of unavailability. 10. The Employer agrees not to use E-Verify for pre-employment screening of job applicants, in support of any unlawful employment practice, or for any other use that this MOU or the E-Verify User Manual does not authorize. 11. The Employer must use E-Verify for all new employees. The Employer will not verify selectively and will not verify employees hired before the effective date of this MOU. Employers who are Federal contractors may qualify for exceptions to this requirement as described in Article II.B of this MOU. 12. The Employer agrees to follow appropriate procedures(see Article III below) regarding tentative nonconfirmations. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. Further, when employees contest a tentative nonconfirmation based upon a photo mismatch, the Employer must take additional steps (see Article I II.B. below) to contact DHS with information necessary to resolve the challenge. 13. The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or DHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a.1(I))that the employee is not work authorized.The Employer understands that an initial inabiity of the SSA or DHS automated verification system to verify work authorization, a tentative nonconfirmation, a case in continuance (indicating the need for additional time for the government to resolve a case), or the finding of a photo mismatch, does not establish, and should not be interpreted as, evidence that the employee is not work authorized. In any of such cases, the employee must be provided a full and fair opportunity to contest the finding, and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status Page 3 of 17 E-Verify MOU for Employers Revision Date 06/01/13 „„.,, ,,,4ce,, a ✓/ u,Pill( - s-VeriFy Company ID Number: 798869 (including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, withholding pay, refusing to assign the employee to a Federal contract or other assignment, or otherwise assuming that he or she is unauthorized to work)until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued. If the employee does not choose to contest a tentative nonconfirmation or a photo mismatch or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment. Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464- 4218 (customer service) or 1-888-897-7781 (worker hotline). 14. The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 274B of the INA as applicable by not discriminating unlawfully against any individual in hiring, firing, employment eligibility verification, or recruitment or referral practices because of his or her national origin or citizenship status, or by committing discriminatory documentary practices. The Employer understands that such illegal practices can include selective verification or use of E-Verify except as provided in part D below, or discharging or refusing to hire employees because they appear or sound "foreign” or have received tentative nonconfirmations. The Employer further understands that any violation of the immigration-related unfair employment practices provisions in section 274B of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject the Employer to back pay awards, compensatory and punitive damages. Violations of either section 274B of the INA or Title VII may also lead to the termination of its participation in E-Verify. If the Employer has any questions relating to the anti-discrimination provision, it should contact OSC at 1-800-255-8155 or 1-800-237-2515(TDD). 15. The Employer agrees that it will use the information it receives from E-Verify only to confirm the employment eligibility of employees as authorized by this MOU. The Employer agrees that it will safeguard this information, and means of access to it(such as PINS and passwords), to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU, except for such dissemination as may be authorized in advance by SSA or DHS for legitimate purposes. f personal nfo 16. The Employer agrees to notify DHS immediately authorizedthe event of a breach access to E-Verify personal data.l Allrmation. Breaches are defined as loss of control or suspected or confirmed breaches should be reported by calling 1-888-464-4218 or via email at E-Verify dhs.gov. Please use"Privacy Incident—Password"in the subject line of your email when sending a breach report to E-Verify. 17. The Employer acknowledges that the information it receives from SSA is governed by person thewho rivacy Act (5 U.S.C. § 552a0)(1) and (3)) and the Social Security Act (42 U.S.C. 1306(a)). Any obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties. 18. The Employer agrees to cooperate withDHS DHS, SSA, then e1r contractors and other agents, upon pliance monitoring and evaluation of E-Verify, which includes permitting Page 4 of 17 E-Verify MOU for Employers 1 Revision Date 06/01/13 s t2 1,/,‘", E-Ver teI� t:'- .� n Company ID Number: 798869 reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the Employer's use of E-Verify, and to respond in a prompt and accurate manner to DHS requests for information relating to their participation in E-Verify. 19. The Employer shall not make any false or unauthorized claims or references about its participation in E-Verify on its website, in advertising materials, or other media. The Employer shall not describe its services as federally-approved, federally-certified, or federally-recognized, or use language with a similar intent on its website or other materials provided to the public. Entering into this MOU does not mean that E-Verify endorses or authorizes your E-Verify services and any claim to that effect is false. 20. The Employer shall not state in its website or other public documents that any language used therein has been provided or approved by DHS, USCIS or the Verification Division, without first obtaining the prior written consent of DHS. 21. The Employer agrees that E-Verify trademarks and logos may be used only under license by DHS/USCIS (see M-795 (Web)) and, other than pursuant to the specific terms of such license, may not be used in any manner that might imply that the Employer's services, products, websites, or publications are sponsored by, endorsed by, licensed by, or affiliated with DHS, USCIS, or E-Verify. 22. The Employer understands that if it uses E-Verify procedures for any purpose other than as authorized by this MOU, the Employer may be subject to appropriate legal action and termination of its participation in E-Verify according to this MOU. B. RESPONSIBILITIES OF FEDERAL CONTRACTORS 1. If the Employer is a Federal contractor with the FAR E-Verify clause subject to the employment verification terms in Subpart 22.18 of the FAR, it will become familiar with and comply with the most current version of the E-Verify User Manual for Federal Contractors as well as the E-Verify Supplemental Guide for Federal Contractors. 2. In addition to the responsibilities of every employer outlined in this MOU, the Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must verify the employment eligibility of any "employee assigned to the contract" (as defined in FAR 22.1801). Once an employee has been verified through E-Verify by the Employer, the Employer may not create a second case for the employee through E-Verify. a. An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor in the E-Verify program within 30 calendar days of contract award and, within 90 days of enrollment, begin to verify employment eligibility of new hires using E-Verify. The Employer must verify those employees who are working in the United States, whether or not they are assigned to the contract. Once the Employer begins verifying new hires, such verification of new hires must be initiated within three business days after the hire date. Once enrolled in E Verify as a Federal contractor, the Employer must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later. Page 5 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 E -Verif - Company ID Number: 798869 b. Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to begin verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within three business days after the date of hire. If the Employer is enrolled in E-Verify as a Federal contractor for 90 calendar days or less at the time of contract award,the Employer must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract. Such verification of new hires must be initiated within three business days after the date of hire. An Employer enrolled as a Federal contractor in E-Verify must begin verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later. c. Federal contractors that are institutions of higher education (as defined at 20 U.S.C. 1001(a)), state or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency under a performance bond may choose to only verify new and existing employees assigned to the Federal contract. Such Federal contractors may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986. Employers in this category must begin verification of employees assigned to the contract within 90 calendar days after the date of enrollment or within 30 days of an employee's assignment to the contract, whichever date is later. d. Upon enrollment, Employers who are Federal contractors may elect to verify employment eligibility of all existing employees working in the United States who were hired after November 6, 1986, instead of verifying only those employees assigned to a covered Federal contract. After enrollment, Employers must elect to verify existing staff following DHS procedures and begin E-Verify verification of all existing employees within 180 days after the election. e. The Employer may use a previously completed Form 1-9 as the basis for creating an E-Verify case for an employee assigned to a contract as long as: i. That Form 1-9 is complete (including the SSN) and complies with Article II.A.6, ii. The employee's work authorization has not expired, and iii. The Employer has reviewed the Form 1-9 information either in person or in communications with the employee to ensure that the employee's Section 1, Form 1-9 attestation has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U.S. citizen). f. The Employer shall complete a new Form 1-9 consistent with Article II.A.6 or update the previous Form 1-9 to provide the necessary information if: i. The Employer cannot determine that Form 1-9 complies with Article II.A.6, ii. The employee's basis for work authorization as attested in Section 1 has expired or changed, or iii. The Form 1-9 contains no SSN or is otherwise incomplete. Note: If Section 1 of Form 1-9 is otherwise valid and up-to-date and the form otherwise complies with Page 6 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 ,„,.,.„ E NM - er a , ...,0,,,„ Company ID Number: 798869 Article 11.0.5, but reflects documentation (such as a U.S. passport or Form 1-551)that expired after completing Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article II.A.5, subject to any additional or superseding instructions that may be provided on this subject in the E-Verify User Manual. g. The Employer agrees not to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU or to authorize verification of any existing employee by any Employer that is not a Federal contractor based on this Article. 3. The Employer understands that if it is a Federal contractor, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements. C. RESPONSIBILITIES OF SSA 1. SSA agrees to allow DHS to compare data provided by the Employer against SSA's database. SSA sends DHS confirmation that the data sent either matches or does not match the information in SSA's database. 2. SSA agrees to safeguard the information the Employer provides through E-Verify procedures. SSA also agrees to limit access to such information, as is appropriate by law,to individuals responsible for the verification of Social Security numbers or responsible for evaluation of E-Verify or such other persons or entities who may be authorized by SSA as governed by the Privacy Act (5 U.S.C. § 552a), the Social Security Act(42 U.S.C. 1306(a)), and SSA regulations(20 CFR Part 401). 3. SSA agrees to provide case results from its database within three Federal Government work days of the initial inquiry. E-Verify provides the information to the Employer. 4. SSA agrees to update SSA records as necessary if the employee who contests the SSA tentative nonconfirmation visits an SSA field office and provides the required evidence. If the employee visits an SSA field office within the eight Federal Government work days from the date of referral to SSA, SSA agrees to update SSA records, if appropriate, within the eight-day period unless SSA determines that more than eight days may be necessary. In such cases, SSA will provide additional instructions to the employee. If the employee does not visit SSA in the time allowed, E-Verify may provide a final nonconfirmation to the employer. Note: If an Employer experiences technical problems, or has a policy question, the employer should contact E-Verify at 1-888-464-4218. D. RESPONSIBILITIES OF DHS 1. OHS agrees to provide the Employer with selected data from OHS databases to enable the Employer to conduct, to the extent authorized by this MOU: a. Automated verification checks on alien employees by electronic means, and Page 7 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 _ 4s Lv s_veri ry 110111 Company ID Number: 798869 b. Photo verification checks (when avaiable) on employees. 2. DHS agrees to assist the Employer with operational problems associated with the Employer's participation in E-Verify. DHS agrees to provide the Employer names, titles, addresses, and telephone numbers of DHS representatives to be contacted during the E-Verify process. 3. DHS agrees to provide to the Employer with access to E-Verify training materials as well as an E-Verify User Manual that contain instructions on E-Verify policies, procedures, and requirements for both SSA and OHS, including restrictions on the use of E-Verify. 4. DHS agrees to train Employers on all important changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manual. Even without changes to E-Verify, OHS reserves the right to require employers to take mandatory refresher tutorials. 5. OHS agrees to provide to the Employer a notice, which indicates the Employer's participation in E-Verify. DHS also agrees to provide to the Employer anti-discrimination notices issued by the Office of Special Counsel for Immigration-Related Unfair Employment Practices (OSC), Civil Rights Division, U.S. Department of Justice. 6. OHS agrees to issue each of the Employer's E-Verify users a unique user identification number and password that permits them to log in to E-Verify. 7. OHS agrees to safeguard the information the Employer provides, and to limit access to such information to individuals responsible for the verification process, for evaluation of E-Verify, or to such other persons or entities as may be authorized by applicable law. Information will be used only to verify the accuracy of Social Security numbers and employment eligibility, to enforce the INA and Federal criminal laws, and to administer Federal contracting requirements. 8. OHS agrees to provide a means of automated verification that provides (in conjunction with SSA verification procedures) confirmation or tentative nonconfirmation of employees' employment eligibility within three Federal Government work days of the initial inquiry. 9. DHS agrees to provide a means of secondary verification (including updating OHS records) for employees who contest OHS tentative nonconfirmations and photo mismatch tentative nonconfirmations. This provides final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to DHS, unless OHS determines that more than 10 days may be necessary. In such cases, OHS will provide additional verification instructions. ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA 1. If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the notice as directed by E-Verify. The Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify Page 8 of 17 E-Verify MOU for Employers i Revision Date 06/01/13 g a 1111111 Company E-VeriFy Company ID Number: 798869 case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer agrees to provide written referral instructions to employees and instruct affected employees to bring the English copy of the letter to the SSA. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. After a tentative nonconfirmation, the Employer will refer employees to SSA field offices only as directed by E-Verify. The Employer must record the case verification number, review the employee information submitted to E-Verify to identify any errors, and find out whether the employee contests the tentative nonconfirmation. The Employer will transmit the Social Security number, or any other corrected employee information that SSA requests, to SSA for verification again if this review indicates a need to do so. 4. The Employer will instruct the employee to visit an SSA office within eight Federal Government work days. SSA will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 5. While waiting for case results, the Employer agrees to check the E-Verify system regularly for case updates. 6. The Employer agrees not to ask the employee to obtain a printout from the Social Security Administration number database (the Numident) or other written verification of the SSN from the SSA. B. REFERRAL TO DHS 1. If the Employer receives a tentative nonconfirmation issued by DHS, the Employer must promptly notify employees in private of the finding and provide them with the notice and letter containing information specific to the employee's E-Verify case. The Employer also agrees to provide both the English and the translated notice and letter for employees with limited English proficiency to employees. The Employer must allow employees to contest the finding, and not take adverse action against employees if they choose to contest the finding, while their case is still pending. 2. The Employer agrees to obtain the employee's response about whether he or she will contest the tentative nonconfirmation as soon as possible after the Employer receives the tentative nonconfirmation. Only the employee may determine whether he or she will contest the tentative nonconfirmation. 3. The Employer agrees to refer individuals to DHS only when the employee chooses to contest a tentative nonconfirmation. 4. If the employee contests a tentative nonconfirmation issued by DHS, the Employer will instruct the Page 9 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 ... „"v, .:,:fr;,:„.. _ : lig. EVenly Company ID Number: 798869 employee to contact DHS through its toll-free hotline (as found on the referral letter) within eight Federal Government work days. 5. If the Employer finds a photo mismatch, the Employer must provide the photo mismatch tentative nonconfirmation notice and follow the instructions outlined in paragraph 1 of this section for tentative nonconfirmations, generally. 6. The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo mismatch, the Employer will send a copy of the employee's Form 1-551, Form 1-766, U.S. Passport, or passport card to DHS for review by: a. Scanning and uploading the document, or b. Sending a photocopy of the document by express mail (furnished and paid for by the employer). 7. The Employer understands that if it cannot determine whether there is a photo match/mismatch, the Employer must forward the employee's documentation to OHS as described in the preceding paragraph. The Employer agrees to resolve the case as specified by the OHS representative who will determine the photo match or mismatch. 8. DHS will elecxronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. 9. While waiting for case results, the Employer agrees to check the E-Verify system regularly for case updates. ARTICLE IV SERVICE PROVISIONS A. NO SERVICE FEES 1. SSA and OHS will not charge the Employer for verification services performed under this MOU. The Employer is responsible for providing equipment needed to make inquiries. To access E-Verify, an Employer will need a personal computer with Internet access. ARTICLE V MODIFICATION AND TERMINATION A. MODIFICATION 1. This MOU is effective upon the signature of all parties and shall continue in effect for as long as the SSA and OHS operates the E-Verify program unless modified in writing by the mutual consent of all parties. 2. Any and all E-Verify system enhancements by DHS or SSA, including but not limited to E-Verify checking against additional data sources and instituting new verification policies or procedures, will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes. Page 10 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 110111 Company ID Number: 798869 B. TERMINATION 1. The Employer may terminate this MOU and its participation in E-Verify at any time upon 30 days prior written notice to the other parties. 2. Notwithstanding Article V, part A of this MOU, DHS may terminate this MOU, and thereby the Employer's participation in E-Verify, with or without notice at any time if deemed necessary because of the requirements of law or policy, or upon a determination by SSA or OHS that there has been a breach of system integrity or security by the Employer, or a failure on the part of the Employer to comply with established E-Verify procedures and/or legal requirements. The Employer understands that if it is a Federal contractor, termination of this MOU by any party for any reason may negatively affect the performance of its contractual responsibilities. Similarly, the Employer understands that if it is in a state where E-Verify is mandatory, termination of this by any party MOU may negatively affect the Employer's business. 3. An Employer that is a Federal contractor may terminate this MOU when the Federal contract that requires its participation in E-Verify is terminated or completed. In such cases, the Federal contractor must provide written notice to DHS. If an Employer that is a Federal contractor fails to provide such notice, then that Employer will remain an E-Verify participant, will remain bound by the terms of this MOU that apply to non-Federal contractor participants, and will be required to use the E-Verify procedures to verify the employment eligibility of all newly hired employees. 4. The Employer agrees that E-Verify is not liable for any losses, financial or otherwise, if the Employer is terminated from E-Verify. ARTICLE VI PARTIES A. Some or all SSA and DHS responsibilities under this MOU may be performed by contractor(s), and SSA and DHS may adjust verification responsibilities between each other as necessary. By separate agreement with DHS, SSA has agreed to perform its responsibilities as described in this MOU. B. Nothing in this MOU is intended, or should be construed, to create any right or benefit, substantive or procedural, enforceable at law by any third party against the United States, its agencies, officers, or employees, or against the Employer, its agents, officers, or employees. C. The Employer may not assign, directly or indirectly, whether by operation of law, change of control or merger, all or any part of its rights or obligations under this MOU without the prior written consent of OHS, which consent shall not be unreasonably withheld or delayed. Any attempt to sublicense, assign, or transfer any of the rights, duties, or obligations herein is void. D. Each party shall be solely responsible for defending any claim or action against it arising out of or related to E-Verify or this MOU, whether civil or criminal, and for any liability wherefrom, including (but not limited to) any dispute between the Employer and any other person or entity regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by the Employer. E. The Employer understands that its participation in E-Verify is not confidential information and may be disclosed as authorized or required by law and DHS or SSA policy, including but not limited to, Page 11 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 ,,,,. E-VeriFyS k /= a Company ID Number: 798869 Congressional oversight, E-Verify publicity and media inquiries, determinations of compliance with Federal contractual requirements, and responses to inquiries under the Freedom of Information Act (FOIA). F. The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer and DHS respectively. The Employer understands that any inaccurate statement, representation, data or other information provided to DHS may subject the Employer, its subcontractors, its employees, or its representatives to: (1) prosecution for false statements pursuant to 18 U.S.C. 1001 and/or; (2) immediate termination of its MOU and/or; (3) possible debarment or suspension. G.The foregoing constitutes the full agreement on this subject between OHS and the Employer. To be accepted as an E-Verify participant, you should only sign the Employer's Section of the signature page. If you have any questions,contact E-Verify at 1-888-464-4218. Page 12 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 rt� t� ‘,,!11110 Company ID Number: 798869 Approved by: Employer Ferreira Construction Co.,lnc. Name (Please Type or Print) Title Warren J Clark Signature Date Electronically Signed 07/17/2014 Department of Homeland Security—Verification Division Name (Please Type or Print) Title USCIS Verification Division Signature Date Electronically Signed 07/22/2014 Page 13 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 usa Ater ry Company ID Number: 798869 Information Required for the E-Verify Program Information relating to your Company: Ferreira Construction Co.,Inc. Company Name 31 Tannery Road Branchburg, NJ 08876 Company Facility Address Company Alternate Address County or Parish HUNTERDON Employer Identification Number 223334957 North American Industry 237 Classification Systems Code Parent Company Number of Employees 100 to 499 Number of Sites Verified for 4 Page 14 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 y,S E- '0111111/ Company ID Number: 798869 Are you verifying for more than 1 site? If yes, please provide the number of sites verified for in each State: CALIFORNIA 1 site(s) FLORIDA 1 site(s) NEW JERSEY 1 site(s) NEW YORK 1 site(s) Page 15 of 17 E-Verify MOU for Employers Revision Date 06/01/13 E-VeriFy < IBllll Company ID Number: 798869 Information relating to the Program Administrator(s)for your Company on policy questions or operational problems: Name Warren J Clark Phone Number (908)534-8655 Fax Number (908)534-8656 Email Address wclark@ferreiraconstruction.com Page 16 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 � ,aji!":, ni.z r Ev Company ID Number: 798869 Page intentionally left blank Page 17 of 17 E-Verify MOU for Employers I Revision Date 06/01/13 Colter County Administrative Services Department COLLIER COUNTY SOLICITATIONS SUBSTITUTE W—9 Request for Taxpayer Identification Number and Certification In accordance with the Internal Revenue Service regulations, Collier County is required to collect the following information for tax reporting purposes from individuals and companies who do business with the County(including social security numbers if used by the individual or company for tax reporting purposes). Florida Statute 119.071(5) require that the county notify you in writing of the reason for collecting this infurmoUon, which will be used for no other purpose than herein stated. Please complete all information that applies to your business and return with your quote or proposal. 1. General Information(provide all information) Taxpayer Name Ferreira Construction Co.,Inc. (as shown on income tax return) Business Name Ferreira Construction Southern Division Co. Inc. ifferent from taxpayer name)'Address 31 Tannery Road City Branchburg State New Jersey Zip 08876 Telephone 908-534-8655 FAX 808-534'8856 Email fc@fenoiracmwhnoVon.omm Order Information Remit/Payment Information Address 7l2OS.Kanner Hwy. Addmnu71208.Kanner Hwy. City Stuart State FL Zip 34097 City StuortSta1 FL zip 34907 FAX 772-286-5139 FAX 772-286-5123 Email lcimbaKah@ferrei/aconmtruoiion.com Email oakers@feneironooatmdUon.com 2. Company Status(check only one) Individual/Sole Proprietor XX Corporation __-Partnership _Tax Exempt(Federal income tax-exempt entity —Limited Liability Company under Internal Revenue Service guidelines IRC 501 (c)3) Enter the tax classification (D Disregarded Entity, C=Corporation, P=Partnership) 3. Taxpayer Identification Number(for tax reporting purposes only) Federal Tax Identification Number(TIN) 22-3334957 (Vendors who do not have a TIN,will be required to provide a social security number prior to an award of the contract.) 4. Sign and Date Form Certification:Under penalties of perjury, /certi&that the information shown on this form is correct to my knowledge. Signature Date 1D1/17 / JohnCiabaft»n / / PhnneNu�ber772�21�130 Title Vice President '__'--_ 20 Construction Services Agreement:Revised 06152017 State of Florida Department of State I certify from the records of this office that FERREIRA CONSTRUCTION SOUTHERN DIVISION CO. INC. is a New Jersey corporation authorized to transact business in the State of Florida, qualified on April 9, 2004. The document number of this corporation is F04000001981. I further certify that said corporation has paid all fees due this office through December 31, 2017, that its most recent annual report/uniform business report was filed on January 12, 2017, and that its status is active. I further certify that said corporation has not filed a Certificate of Withdrawal. Given under my hand and the Great Seal of the State of Florida at Tallahassee,the capital, this the Twelveth day of January, 2017 cfa S Y•>7_47.0.-4i. " k4% L:-.11;477-7 { 7-1•-t.:::I •� `.r; Secretary of State 90 rim Tracking Number:CC3698938896 To authenticate this certificate,visit the following site,enter this number,and then follow the instructions displayed. https:l/services.su n bia.org/Filings/CertificateofStatus/CertificateAu then tica do n **********PAGE INTENTIONALLY LEFT BLANK********** 21 Construction Services Agreement:Revised 06152017 Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement form attached to the Bidding Documents within ten (10) calendar days and deliver the Surety Bond or Bonds and Insurance Certificates as required by the Contract Documents.The bid security attached is to become the property of the Owner in the event the Agreement, Insurance Certificates and Bonds are not executed and delivered to Owner within the time above set forth, as liquidated damages,for the delay and additional expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance Certificates and Bonds within the required time period. In the event of such failure, the total amount of Owner's damages,will be difficult, if not impossible,to definitely ascertain and quantify. It is hereby agreed that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the event it fails to execute and deliver the Agreement, Insurance Certificates, and Bonds as required hereunder. The Successful Bidder hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely manner. Upon receipt of the signed and approved agreement and Purchase {]rdmr, the undersigned proposes to commenneworkatUnosi&ywithinfive (5) om|endardayohnmthem»mmencementdmhestipulated in the written Notice to Proceed unless the PManager, in writing, subsequently notifies the Contractor of a modified (later) commencement date. The undersigned further agrees to substantially complete all work coveredby this ` 'Bid within one hundred and �memt� /��Q� consecutive calendar days, computed by excluding the commencement date and including the last day of such period, and to be fully completed to the point of final acceptance by the Owner within five (5) consecutive calendar days after Substantial Completion, computed by excluding commencement date and including the last day of such period. Respectfully Submitted: State of Florida County of Martin John Ciabattari , being first duly sworn on oath deposes and says that the Bidder on the above Bid is organized as indicated and that all statements herein made are made on behalf of such Bidder and that this deponent is authorized to make them. John Ciabattari , also deposes and says that it has examined and carefully prepared its Bid from the Bidding Documents, including the Contract Drawings and Specifications and has checked the same in detail before submitting this Bid;that the statements contained herein are true and correct. (a) Corporation The Bidder is a corporation organized and existing under the laws of the State of New Jersey ,vvhich operates under the legal name of Ferreira Construction Southern Division Co., Inc, , and the full names of its officers are as follows: President Nelson Ferreira Secretary Luis PachecD Treasurer Luis Pacheco Manager 22 Construction Services Agreement Revised 061520 7 The officers listed in the attached resoultion are X authorized to sign construction bids and contracts for the company by action of its Board of Directors taken Januar:6, 2017 , a certified copy of which is hereto attached (strike out this last sentence if not applicable). (b) Co-Partnership The Bidder is a co-partnership consisting of individual partners whose full names are as follows: --___ ----_-____ The co-partnership does business under the legal name of: (c) Individual The Bidder is an individual whose full name is , and if operating under a trade name, said trade name is Complete for information contained in (a) Corporation, (b) Co-Partnership or (c) Individual from previous page. DATED 221/1:1 Ferreira Construction Southern Division Co., Inc. *ppAli .v.,. TO Legal Entity J.IRE LAND By: John Ciabattari can........,.. iflif Name of,Bidder;_iy( peA) -1OAO-V-1 /4:14.F42-S --) // / / ' / , Witnessanature / / Vice President Title 23 Construction Services AgreementRevised 06152017 STATE OF Florida COUNTY OF Martin The foregoing instrument was acknowledged before me this lst day of December , 20 17 , by John Ciabattari as Vice President of Ferreira Construction Southern Division Co., Inc , a New Jersey corporation, on behalf of the corporation. 1-leisfle.is personally known to me or has produced as identification and did (did not)take an o- ft 4111 ‘iii I My Commission Expires 8/10120 fg ure of otary) JOB J,IRELAND = • , • 4` MY COMMISSION#GG 016798 NAME: Job J. Ireland EXPIRES:August 10,2020 °*••WO, Bonded ThNotary Pebk drideAoters (Legibly Printed) (AFFIX OFFICIAL SEAL) Notary Public, State of Fiorida Commission No.: GG016798 24 Construction Services Agreement Revised 06152017 FERREIRA FERR•EIRA CONSTRUCTION SOUTHERN DIVISION CO,INC. State of Florida County of Martin On this 1st day of December 2017, I certify that the attached document,is a true,exact, complete, and \ ti�Ddated]anuary6' 2O27, presenteozwrncnythe una|t�re��upynnadebYn«eofCorPorate�asou cti Inc. who is document's custodian, Dictinio Garcia, Senior Vice president of Ferreira Construction Co.,.' . personally known to me. /„„/ '- / / ^�^^� , ~�*�w' DictinioGmrcia Senior Vice President ' /l ��N ' � )44 AY. ' JOS J IRELAND i„,i it 1,4 MY COMMISSION#00 016798 ' Notary Public / �,;;;VYBonded'mvWary Public°==~ e, ~___ ` — --- n��� ---- — ----------�----- — — — -- �O��12� F���72)�0�' 13� v«ww��r�,n�u° .=".. ~ 71�DS KannerStuart, L34��7 Phone (772) . S. Hwy, GC License#CGC1509418 An Equal Opportunity Employer „Irir,„, ERRE:1RA CORPORATE RESOLUTION UNANIMOUS WRITTEN CONSENT OF THE DIRECTORS OF FERREIRA CONSTRUCTION CO., INC. IN LIEU OF A MEETING The undersigned, being the sole Director of FERREIRA CONSTRUCTION CO., INC a New Jersey s of Section 14A:6-16, Corporations, General of corporation <m* 'Corporation"), p"'""”" t~ ^'~ adoption ofan�doeahenabyadup�.thah»|��mg the New Jersey S���m`hereby consents m»ww/ Swthe�" of�e' otm meet�gdu\yo��ed reso|ubuns. \ubaeffeo�easthough adopted bythe dneommCorporation and held: LET IT BE RESOLVED. that the following persons are officers of the Corporation the same to serve at the pleasure of the Board: President. Nelson Ferreira Sr. Vice President!CFO; Jerry Killian Executive Vice President DichnioGarda Vice President: Nancy Vliet Vice President of Field Operations: Brian Delpome Vice President of NY Operations; Tom Groark Vice President: Raymond Finnegan Vice President of Stuart, Florida Operations: John Ciabattari Vice President of Medley, Florida Operations: Danny Garcia Vice President of Ferreira Coastal Operations: BrondonPeneick Secretary/Treasurer. Luis Pacheco LET IT BE FURTHER RESOLVED. the officers of Ferreira Construction Co., Inc. has authority to sign all contracts and bind the corporation IN WITNESS WHEREOF, I have set my hand on this 6th d o January, 2017 / | / ! FERREIRA CONST- CT|UN CO, i0C.\l/ / \ N.ko Director a~~~~ 31 Tannery Road,Branchburg, NJ 08876 Phone: (908) 655 Fax: 1908>534-865G www.ferreiraconstruction,com All cp"^/opvn^vmtycmnmvc. BID BOND KNOW ALL MEN BY THESE PRESENTS, that we Ferreira Construction Southern Division Co..Inc. 7120 S.Kanner Highway.Stuart,FL 34997 (herein after called the Principal) and Fidelity and Deposit Company of Maryland.1299 Zurich Way,Schaumburz,IL 60196 , (herein called the Surety), a corporation chartered and existing under the laws of the State of Maryland with its principal offices in the city of Schaumburg and authorized to do business in the State of Florida are held and firmly bound unto the Collier County Board of Count+,,Commissioners (hereinafter called the Owner), in the full and just sum of Five Percent of the Total Amount Bid dollars ($ 5% )good and lawful money of the United States of America,to be paid upon demand of the Owner, to which payment well and truly to be made, the Principal and the Surety bind themselves,their heirs, and executors, administrators, and assigns,jointly and severally and firmly by these presents. Whereas, the Principal is about to submit, or has submitted to the Owner, a Bid for furnishing all labor, materials, equipment and incidentals necessary to furnish, install, and fully complete the Work on the Project known as Bid No. 18-7239 Dredging of Wiggins and Doctors Passes. NOW,THEREFORE, if the Owner shall accept the Bid of the PRINCIPAL and the PRINCIPAL shall enter into the required Agreement with the Owner and within ten days after the date of a written Notice of Award in accordance with the terms of such Bid, and give such bond or bonds in an amount of 100% the total Contract Amount as specified in the Bidding Documents or Contract Documents with good and sufficient surety for the faithful performance of the Agreement and for the prompt payment of labor, materials and supplies furnished in the prosecution thereof or, in the event of the failure of the PRINCIPAL to enter into such Agreement or to give such bond or bonds, and deliver to Owner the required certificates of insurance, if the PRINCIPAL shall pay to the OBLIGEE the fixed sum of t .,5%of Total Bid Amt. noted above as liquidated damages, and not as a penalty, as provided in the Bidding Documents,then this obligation shall be null and void,otherwise to remain in full force and effect. IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly signed and sealed this 1st day of December , 20 17 • \\ 2 ...c tr__..../ Ferreira Const. ion South Di .-ion Co.,Inc. -larintiortr ',4- ,• : BY 4. J 4NCAMTOMZIi VCE PRE51- ( A(,( Fidelity and Deposit Company of Maryland Suretyt- ( By. ,4/?._ttut-ochn57.9, e (Seal) • ,-, , \-...,____ Theresa I Foley,Attorn - -Fact ' : °' • Countersigned '''---------- .1, . ,.%•" <5. Local Local Resident Producing Agent for Fidelity and Deposit Company of Maryland . •, ,,,, ,.._. : . , . .,!) ‘.•,'-';. *kr ,,,?".; T4'' .': ,:.,•,4,...,,,.: ,r `• • • "'-i c , 25 Construction Services Agreement Revised 06152017 ACKNOWLEDGEMENT OF CONTRACTOR, IF A CORPORATION STATE OF FLORIDA COUNTY OF � ON THE DAY OF K-CEKkH7 _ 2017, 8EFORE ME PERSONALLY CAME T�UW �\���k3Th[U TOKAEWHOBE|NG8YiNEQULY8VVORN DID DEPOSE �u�`., ��`r«/r�` mrgKNOWN, ' � 0� RESIDESAND SAY THAT(S)H[ U�AT �� LAI FhOK Vn ,THAT(5)HE |STHE \/&^E P0c5<lE+J~ _ OF Ferreira Construction Southern Division Co., Inc. THE CORPORATION DESCRIBED IN AND WHICH EXECUTED THE ABOVE INSTRUMENT;AND THAT(S)HE SIGNED HIS/HER NAME THERETO BY ORDER OF THE BOARD OF DIRECTORS OF SAID CORPORATION. .�� -_ LAN EXPIRES:August 10,2020 ' \:":" MY COMMISSION#GG 016708 ' /N���ryPuN� J0b j� [RE��`[V� __- Oderveriters ACKNOWLEDGEMENT OF SURETY STATE OF NEW YORK COUNTY OF NASSAU ON THE 1", DAY OF December 2017 BEFORE ME PERSONALLY CAME Theresa J Foley TO ME KNOWN,WHO, BEING BY ME DULY SWORN, DID DESPOSE AND SAY THAT SSHE IS THE ATTORNEY-IN- FACT OF Fidelity and Deposit Company of Maryland THE CORPORATION DESCRIBED IN AND WHICH EXECUTED THE ABOVE INSTRUMENT;THAT HE KNOWS THE SEAL OF SAID CORPORATION;THAT ONE OF THE SEALS AFFIXED TO THE FOREGOING INSTRUMENT IS SUCH SEAL;THAT IT WAS SO AFFIXED BY ORDER OF THE BOARD OF DIRECTORS OF SAID CORPORATION;AND THATS HE SIGNED HER NAME THERETO BY LIKE ORDER. » .w// Notary Public ( / SHARLINE R. ROGERS NOTARY PUBLtC,State of New York No,01R06204400 Qualified in Queens County Commission Expires April 20,2021 EXTRACT FROM BY-LAWS OF THE COMPANIES "Article V.Section 8.Attornevs-in-Fact. The Chief Executive Officer,the President,or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto;and may with or without cause modify of revoke any such appointment or authority at any t i me." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate;and I do further certify that Article V.Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile tinder and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may he affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such facsimile signature and seal shall he valid and binding on the Company." This Power of Attorney and Certificate may he signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990. RESOLVED: 'That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice-President, Secretary,or Assistant Secretary of the Company,whether made heretofore or hereafter,wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed. [N TESTIMONY WHEREOF,I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this day of -0 DEC 01 2017 - OSEAL 19,, ma .11 .4. •• ..f4°•",;110.0" 1 Michael Bond,Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND, PLEASE SUBMIT ALL REQUIRED INFORMATION TO: Zurich American Insurance Co. Attn: Surety Claims t a IVOr 1299 Zurich Way Schaumburg. IL 60196-1056 •• ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY , KNOW ALL MEN BY THESE PRESENTS:That the ZURICH AMERICAN INSURANCE COMPANY,a corporation of the State of New York.the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY,a corporation of the State of Maryland,and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies), by DAVID MCVICKER,Vice President,in pursuance of authority granted by Article V,Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to he in full force and effect on the date hereof, do hereby nominate, constitute,and appoint Theresa J.FOLEY,Kevin T.WALSH,JR and Michael MARINO,all of Roslyn Heights,New York, EACH its true and lawful agent and Attorney-in-Fact, to make, execute,seal and deliver,for,and on its behalf as surety,and as its act and deed: any and all bonds and undertakings,and the execution of such bonds or undertakings hi pursuance of these presents,shall he as binding upon said Companies,as folly and amply,to all intents and purposes,as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. . The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V,Section 8,of the By-Laws of said Companies,and is now in force, IN WITNESS WHEREOF,the said Vice-President has hereunto subscribed hisiher names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this 19th day of June,A.D.2017. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND C4CostAti), ap ro.t, tr -.. . % 4-';'.P."'. T. el'ir7r°•• -SEAL 1 4-- 3442.41. 6, mot. '4..4., \12e.•--- •o•s".0 • i 11 1e / , ' e BY: _ Assistant Secretary Vice President Dawn E.Brown David McVicker State of Maryland County of Baltimore On this 19th day of June. A.D. 2017, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, DAVID MCVICKER,Vice President,and DAWN E.BROWN,Assistant Secretary,of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument,and acknowledged the execution of same,and being by me duly sworn,depose:h and saith,that he/she is the said officer of the Company aforesaid,and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations, IN TESTIMONY WHEREOF,I have hereunto set Inv hand and affixed my Official Seal the day.and year first above written. ,,..`1!: 7,',„, ,:.,;,:ioNsni,..,?• ,. - f t• , IJ ,,,,r,y;-AT,,,,,eiz„(-,4• , ,,, . -- ;; 0' Constance A.Dunn,Notary Public My Commission Expires:July 9,2019 I FDA-F 093-0146 I 1 . . . I i i ! ' i i FIDELITY AND DEPOSIT COMPANY • • OF MARYLAND :. 600 Red Brook Blvd.,Suite 600,Owings Mills,MD 21117 i ; i Statement of Financial Condition i As Of December 31,2016 i• ASSETS Bonds $ 141,903,342 Stocks 22,845,654 Cash and Short Term investments 3,080,053 Reinsurance Recoverable , 13,996,720 . . .. . . — • Other Accounts Receivable 27,147,872 TOTAL ADMITTED ASSETS. $ 208,973,64.1 LIABILITIES,SURPLUS AND OTHER FUNDS • Reserve for Taxes and Expenses $ 896,428 • Ceded Reinsurance Premiums Payable 40,193,693 Securities Lending Collateral Liability , 0 ToTALLIABILITIES.....„.....................-.................,,...„-._.,...............................,.........-..... $ 41,090,121 Capital Stock,Paid Up $ 5,000,000 Surplus 162,883,521 •• Surplus as regards Policyholders 167,883,520 ToTAL $ 208,973,641 _ . , Securities carried at$62,166,344 in the above statement are deposited with various states as required by law. Securities carried on the basis prescribed by the National Association of Insurance Commissioners. On the basis of market quotations for all bonds and stocks owned,the Company's total admitted assets at December 31,2016 would be$209,350,832 and surplus as regards policyholders$168,260,711. I,DENNIS F.KERRIGAN,Corporate Secretary of the FIDELITY AND DEPOSIT COMPANY OP MARYLAND,do hereby ,• .• certify that the foregoing statement is a correct exhibit of the assets and liabilities of the said Company on the 31st • day of December,2016. (n : ; for rr'ate Secretary .. State of Illinois 1 SS: City of Schaumburg Subscribed and sworn to,before me,a Notary Public of the State of Illinois,in the City of Schaumburg,this Isi day of March,2017. , Ci Notary Public .,,,-°' \)v,,,,,;,.), v......2...-0-e-42...."-&-&-e•-dr.-......e.,,-0-.? DNIFTYL JOIiqa-Fi ( /441"r4e.'''", OFFICIAL 4 NOWry f',Ua of•!... :: Iltinos tily Ounmission b:piros i a t Formtary 01 24,28 '-;:7 i A 6',•:” , 1- . , . ,,_ ,, .„ •,- '. , , . '. ''-„16'.:" ,'") .., ,- • •,, ,t,:?#r y",0. ,.., THIS SHEETMUST BE SIGNED BY VENDOR BOARD OF COUNTY COMMISSIONERS COLLIER COUNTY, FLORIDA Procurement Services Division BIDDERS CHECK LIST IMPORTANT: Please read carefully, sign in the spaces indicated and return with your Bid. Bidder should check off each of the following items as the necessary action is completed: 1. The Bid has been signed. 2. The Bid prices offered have been reviewed. 3. The price extensions and totals have been checked. 4. Any required drawings, descriptive literature, etc. have been included. 5. Any d |i information required is included, O. Immigration Affidavit completed and the company's E-Verify profile page or memorandum of understanding . 7. Ce�i�cot8ofAuthodh/toConduct Business inState ofFlorida and the [�ountys Substitute W9 8. If required, the amount of Bid bond has been checked, and the Bid bond or cashier's check has been included. 9. Any addenda have been signed and included. 10. The Bid will be uploaded in time to be received no later than the specified opening date and time, otherwise the Bid cannot be considered. Ferreira Construction Southern Division Co , Inc Bidder Name � �7 // I Vice President 17/1/17 Signature & Title Date JVhnCiabaM3h 26 Construction ServiceAgreement:Revise06152017 EXHIBIT 1.A GRANT CONTRACT PROVISIONS FLORIDA DEPARTMENT OF ENVIRONMENTAL PROTECTION The supplemental conditions contained in this section are intended to cooperate with, to supplement, and to modify the general conditions and other specifications. In cases of disagreement with any other section ' of this contract,the Supplemental Conditions shall govern. Contractor means an entity that receives a contract. The services performed by the awarded Contractor shall be in compliance with all applicable grantor regulations/requirements, and additional requirements specified in this document. It shall be the awarded Contractor's responsibility to acquire and utilize the necessary manuals and guidelines that apply to the work required to complete this project. In general, 1)The contractor(including all subcontractors)must insert these contract provisions in each lower tier contracts(e.g. subcontract or sub-agreement); 2)The contractor(or subcontractor)must incorporate the applicable requirements of these contract provisions by reference for work done under any purchase orders, rental agreements and other agreements for supplies or services; 3) The prime contractor is responsible for compliance with these contract provisions by any subcontractor,lower-tier subcontractor or service provider. i t 1 1 i 1 GCP-1 EXHIBIT 1.A GRANT CONTRACT PROVISIONS STATE GRANT PROVISIONS Equal Employment Opportunity:No person on the ground of race,creed,color,religion,national origin, age, gender, or disability, shall be excluded from participation in; be denied the proceeds or benefits of, otherwise subjected to discrimination. Discriminatory Vendor List: In accordance with Section 287.134, Florida Statutes, an entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work,may not submit bids on leases of real property to a public entity,may not be awarded or perform work as a contractor,supplier,subcontractor,or consultant under a contract with any public entity,and may not transact business with any public entity. Interest of Members of Congress: No member of or delegate to the Congress of the United States shall be admitted to any share or part of this contract or to any benefit arising there from. Interest of Public Officials:No member,officer,or employee of the public body or of a local public body during his tenure or for two years thereafter shall have any interest,direct or indirect,in this contract or the proceeds thereof.For purposes of this provision,public body shall include municipalities and other political subdivisions of States;and public corporations,boards,and commissions established under the laws of any State. Lobbying: No funds received pursuant to this Agreement may be expended for lobbying the Legislature, the judicial branch or a state agency. Record Retention — A. The contractor shall maintain and retain sufficient records demonstrating its compliance with the terms of the Agreement for a period of at least five (5) years after final payment is made and shall allow the County,the State,or its authorized representatives access to such records for audit purposes upon request. Inspector General Cooperation: The Parties agree to comply with Section 20.055(5), Florida Statutes, for the inspector general to have access to any records, data and other information deemed necessary to carry out his or her duties and incorporate into all subcontracts the obligation to comply with Section 20.055(5),Florida Statutes. Conflict of Interest: This Contract/Work Order is subject to chapter 112, F.S. The vendor shall disclose the name of any officer, director,employee,or other agent who is also an employee of the State. Grantee shall also disclose the name of any State employee who owns,directly or indirectly,more than a five percent l (5%)interest in the Contractor's company or its affiliates. In order to comply with Florida Auditor General report 201 4-064 regarding conflicts of interest and to be consistent with Section 287, 057(17)(a)(1 ), F.S., all monitoring data and statistical analysis must be provided directly and concurrently from the monitor to the FDEP/County/permittee/engineering consultant. Diversity—All contracting and subcontracting opportunities afforded by this solicitation/contract embrace diversity enthusiastically. The award of subcontracts should reflect the full diversity of the citizens of the State of Florida. Finns qualifying under this solicitation are encouraged to submit bids/proposals. Award of this contract will be conditioned upon satisfying the requirements of this bid specification. These requirements apply to all bidders/offerors,including those who qualify as a Minority Business vendor. A GCP-2 EXHIBIT 1.A GRANT CONTRACT PROVISIONS list of minority owned firms that could be offered subcontracting opportunities may be obtained by contacting the Office of Supplier Diversity at(850)487-0915 Applicable Laws - The contractor shall comply with all applicable federal, state and local rules and regulations in providing services to the County. The contractor acknowledges that this requirement includes, but is not limited to, compliance with all applicable federal, state and local health and safety rules and regulations. Pursuant to Section 255.0991, F.S.local vendor preference is not applicable Scrutinized Companies—Pursuant Section 215.473, F.S.the Local Sponsor subcontractor certifies that it is not listed on the Scrutinized Companies with Activities in Sudan List, the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List,and/or Scrutinized Companies with Activities in Israel List(eff. 10.1.2016). Created Pursuant to Subsection 287.135(5),F.S.,the subcontractor agrees the County may immediately terminate this Agreement for cause subcontractor is found to have submitted a false certification or if the subcontractor is placed on the Scrutinized Companies list during the term of the Agreement. GCP-3 EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES GRANT CERTIFICATIONS AND ASSURANCES THE FOLLOWING DOCUMENTS NEED TO BE RETURNED WITH SOLICIATION DOCUMENTS BY DEADLINE TO BE CONSIDERED RESPONSIVE 1. Certification Regarding Debarment, Suspension, and Other Responsibility Matters - Primary Covered Transactions 2. Certification regarding Lobbying 3. Conflict of Interest 4. Anticipated DBE,M/WBE or VETERAN Participation Statement 5. Opportunity List for Commodities and Contractual Services and Professional Consultant Services 6. Scrutinized Companies Certification 7. Acknowledgement of Grant Terms and Conditions GCA- 1 EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Certification Regarding Debarment,Suspension,and Other Responsibility Matters Primary Covered Transactions (1) The prospective primary participant certifies to the best of its knowledge and belief,that it and its principals: (a) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency; (b) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain,or performing a public(Federal,State or local)transaction or contract under a public transaction;violation of Federal or State antitrust statutes or commission of embezzlement,theft,forgery, bribery,falsification or destruction of records,making false statements,or receiving stolen property; (c) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity(Federal, State or local)with commission of any of the offenses enumerated in paragraph(l)(b)of this certification; and (d) Have not within a three-year period preceding this application/proposal had one or more public transactions(Federal, State or local)terminated for cause or default. (2) Where the prospective primary participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal. John Ciabattari Dredging of Wiggins and Doctors Passes Name Project Name Vice President 18-7239 Title Project Number Ferreira Construction Southern Division Co., Inc. 22-3334957 Firm Tax ID Number 031760697 DUNS Number 7120 S. Kanner Hwy., Stuart, Florida 34997 Street Addres City,St ,i s Si:• ture GCA -2 EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Certification Regarding Lobbying Ferreira Construction Southern Division Co., Inc. The undersigned (Vendor/Contractor)certifies,to the best of his or her knowledge and belief,that: (1)No State appropriated funds have been paid or will be paid,by or on behalf of the undersigned,to any person for influencing or attempting to influence an officer or employee of an agency, a member of the Legislature, an officer or employee of the judicial branch,or an employee of a State agency in connection with the awarding of any State contract,the making of any State grant,the making of any State loan,the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any State contract, grant, loan,or cooperative agreement. (2)No grantee,nor its persons or affiliates,may employ any person or organization with funds received pursuant to any State agreement for the purpose of lobbying the Legislature, the judicial branch, or a State agency. The purpose of lobbying includes,but is not limited to,salaries,travel expenses and per diem,the cost for advertising, including production costs; postage; entertainment; and telephone and telegraph; and association dues. The provisions of this paragraph supplement the provisions of section 11.062, Florida Statutes,which is incorporated by reference into this solicitation,purchase order or contract. (3)The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including subcontracts, subgrants, and contracts under grants, loans, and cooperative agreements)and that all subrecipients shall certify and disclose accordingly. The Vendor/Contractor, ,certifies or affirms the truthfulness and accuracy of each statement of its certification and disclosure, if any. In addition, the Contractor understands and agrees that the provisions of 11.062,Florida Statutes., apply to this certification and disclosure,if any. John Ciabattari Name of Authorized Official Vice President , Title �< Signature of Vendor/Contractor's Authorized Official { 12/1/17 Date GCA - 3 EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Conflict of Interest Certification 18-7239 Collier County Solicitation No. I, John Ciabattari ,hereby certify that to the best of my knowledge,neither I nor my spouse, dependent child, general partner, or any organization for which I am serving as an officer, director, trustee, general partner or employee, or any person or organization with whom I am negotiating or have an arrangement concerning prospective employment has a financial interest in this matter. I further certify to the best of my knowledge that this matter will not affect the financial interests of any member of my household.Also,to the best of my knowledge,no member of my household;no relative with whom I have a close relationship; no one with whom my spouse,parent or dependent child has or seeks employment; and no organization with which I am seeking a business relationship nor which I now serve actively or have served within the last year are parties or represent a party to the matter. I also acknowledge my responsibility to disclose the acquisition of any financial or personal interest as described above that would be affected by the matter,and to disclose any interest I,or anyone noted above,has in any person or organization that does become involved in,or is affected at a later date by,the conduct of this matter. John Ciabattari ;;01" Name Signature Vice President 12/1/17 Position Date Privacy Act Statement Title I of the Ethics in Government Act of 1978 (5 U.S.C. App.), Executive Order 12674 and 5 CFR Part 2634, Subpart I require the reporting of this information.The primary use of the information on this form is for review by officials of The Justice Department to determine compliance with applicable federal conflict of interest laws and regulations. Additional disclosures of the information on this report may be made: (1) to a federal, state or local law enforcement agency if the Justice Department becomes aware of a violation or potential violation of law or regulations; (2)to a court or party in a court or federal administrative proceeding if the government is a party or in order to comply with a judge-issued subpoena;(3)to a source when necessary to obtain information relevant to a conflict of interest investigation or decision; (4)to the National Archives and Records Administration or the General Services Administration in records management inspections;(5)to the Office of Management and Budget during legislative coordination on private relief legislation; and (6) in response to a request for discovery or for the appearance of a witness in a judicial or administrative proceeding,if the information is relevant to the subject matter.This confidential certification will not be disclosed to any requesting person unless authorized by law.See also the OGE/GOVT-2 executive branch-wide Privacy Act system of records. GCA -4 EXHIBIT LB GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY ANTICIPATED DISADVANTAGED, MINORITY, WOMEN OR VETERAN PARTICIPATION STATEMENT Status will be aerrfe-d. Um:enfasie statuses Will require me PR ME to either pro'ade a revised statement or provide source documentation that salidates a status. A. PRIME VENDOR/CONTRACTOR INFORMATION PRIME NAME PRIME FED NUMBER CONTRACT DOLLAR AMOUNT Ferreira Construction Co., Inc. 22-3334957 $2,098.980.00 15 THE PR€MES FLORIDA{ERT#FIED DISADVANTAGED, yrrELIAN . N I5 THE ACTIVITY OF THIS C-DNTRACT.,.. MINORITY 05 WOMEN BUSiNESSENTERPRISE? D8E? Y N CONSTRUCTION? Y N DBEIMBEiWBEi OR HAVE A SMALL DISADVANTAGED BUSINESS SA.CERTIFICATION FROM THE SMALL BUSINESS MBE? 1' N CONSULTATION? Y N ADMINISTRAT1ON? A SERVICE DISABLED VETERAN, WBE? t N OTHER? s N SDB SA? Y N IS THS SUBMISS°=0,N A REVISION? v N IF YES,R.E✓'SION PLUMBER B. IF PRIME HAS SUBCONTRACTOR OR SUPPLIER WHO IS A DISADVANTAGED MINORITY,WOMEN-OWNED,SMALL BUSINESS CONCERN OR SERVICE DISABLED VETERAN,PRIME IS TO COMPLETE THIS NEXT SECTION DBE M/WBE SUBCONTRACTOR OR SUPPLIER TYPE OF WORK OR ETHNICITY CODE SUB/SUPPLIER PERCENT OF CONTRACT VETERAN NAME SPECIALTY See Be4ow) DOLLAR AMOUNT DOLLARS TOTALS C. SECTION TO BE COMPLETED BY PRIME VENDOR/CONTRACTOR NAME OF SUBMIT ItR DATE mu OF SUBMITTER John Ciabattari 12/1/17 Vice President EMAIL ADDRESS OF PRIME[SUBMITTER) TELEPHONE NUMBER FAX NUMBER jciabattari@ferreiraconstruction.com 772-286-5123 772-286-5139 NOTE.This information is used to track and report anticipated DBE Or MBE participation in federaL•y,.fUswed contracts. The anticipated DBE or MBE amount is voluntary and will not become part of the contractual terms. This form must be submitted at time of response to a solicitation I and when awarded a County contract,the prime will be asked to update the informati.on for the grant compliance files FTMNIClTY CODE black American BA Hispanic A.merit-an HA Native American NA Subcent,Asian American SAA Asian-Pacific American APA Non-MiMNIti Women NMW Other not of any other group listed 0 D.SECTION TO BE COMPLETED BY COLLIER COUNTY DEPARTMENT NAME COLLIER CONTRACT 9[IFB'RfP o'PO/REO} GRANT PROGRAM/CONTRACT ACCEPTED BY: ' DATE. GCA - 5 EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES pID OPPORTUNITY LIST FOR COMMODITIES AND CONTRACTUAL SERVICES AND PROFESSIONAL CONSULTANT SERVICES rt is the policy of Cattier County that disadvantaged businesses and minority vendors,as defined in the Code of Federal Regulations(CFR)or f"ionda Statutes In),must have the oppomunity to participate on contracts with federal and//or state grant assistance. Prime Contractor/Prime Consultant. Ferreira Construction Southern Division Co., Inc. Address and Phone Number 7120 S. Kanner Hwy., Stuart, FL 34997 772-286-5123 Procurement Number/Arfvertisemerst Number: 18-7239 The list below is intended to be a listirs:of firms that are,or attempting to,participate on the project numbered above. The list must include the firm bidding or quoting as prime,as well as subs and suppliers quoting for participation Prime contractors and consultants must provide information for Numbers 1,2,3,and 4;and,should provide any information they have for Numbers 5,6,7,and B.This form must be submitted with the bid package 1. Federal Tax ID Number: 51-0501765 6.® DEE S Annual Gross Receipts 2_ firm Name_ Sea Diversified. Inc. Non-DBE —•less than$1 million 3. Phone(Number. 5fi1-243-4291) Y Between 51-5 milldam A. address 151 NW 1st Ave. Between$5-10 million Delray Beach, FL 33444 7.9 Subcontractor —Between 510-15million Subconsultant —More than$15 ninon 5. Year Firm Established. 2004 1. Federal Tax ID Number. 59-1117804 6 EiDBE 2. Annual Gross Receipts 2. Firm Name Universal Engineering Non-DBE _oLess than 5 1 million 3. Phone Number 239-995-1997 —Between 5 1-5 million —_ 4. Address 5971 Country Lakes Drive Between$5-10 million 7 Subcontractor Ft. Myers,FL 33905 scontractor Between$10-15 million ® Subconsuhant More than 5 15 million 5. Year Finn Established 1964 1. Federal Tax ID Number: 6.El DBE a,Annual Gross iteceepts 2. Firm Name: Non-DEE _Less than 5 1 minion 3. Phone Number. Between$1.5 minion -- 1. Address Between 5 5-10 maim 7..E SuucontraCOr Between 5 10-15 million Subconsulant More than$15 mi lion `_ 5. Year Firm Established. 1. Federal Tax t0 Number: 6.El DEE 8 Antral Gloss Receipts 2. Firm Name Noy-DEE Less than 5 1 mi Ilan —+ 3 Phone Number Between 1.5 million --... y,Address Between$5-10 million -H Subcontracar Between 10-15 million 5ubcGns ultant _-More than$15 rnation 5 Lear Firm Established . GCA- 6 EXHIBIT I.B GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Acknowledgement of Terms,Conditions and Grant Clauses Flow Down of Terms and Conditions from the Grant Agreement Subcontracts: If the vendor subcontracts any of the work required under this Agreement,a copy of the signed subcontract must be available to the Department for review and approval. The vendor agrees to include in the subcontract that (1) the subcontractor is bound by the terms of this Agreement, (ii) the subcontractor is bound by all applicable state and federal laws and regulations, and (iii) the subcontractor shall hold the Department and Recipient harmless against all claims of whatever nature arising out of the subcontractor's performance of work under this Agreement, to the extent allowed and required by law. The recipient shall document in the quarterly report the subcontractor's progress in performing its work under this agreement. For each subcontract, the Recipient shall provide a written statement to the Department as to whether the subcontractor is a minority vendor as defined in Section 288.703,Fla. Stat. Certification On behalf of my firm, I acknowledge, and agree to perform all of the specifications and grant requirements identified in this solicitation document(s). Vendor/Contractor Name Ferreira Construction Southern Division Co., Inc.Date 12/1/17 Authorized Signature John Ciabattari Address 7120 S. Kanner Hwy., Stuart,Florida 34997 Solicitation/Contract# 18-7239 GCA- 7 EXHIBIT LB GRANT CERTIFICATIONS AND ASSURANCES COLLIER COUNTY Scrutinized Companies Certification Ferreira Construction Southern Division Co., Inc. The undersigned (Vendor/ Contractor) certifies, to the best of his or her knowledge and belief,that it is not listed on the • Scrutinized Companies with Activities in Sudan List, • Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List,and/or • Scrutinized Companies with Activities in Israel List(eff. 10.1.2016),pursuant to Section 215.473,F.S. The subcontractor further agrees the County may immediately terminate this contract for cause if the vendor/contractor is found to have submitted a false certification or is placed on the Scrutinized Companies list during the term of the contract. John Ciabattari Name of Authorized Official Vice President Title -rc`' _ rJj-enc- Signature of Vendor/Contractor's Authorized Official 12/1/17 Date GCA- 8 Page 1 of 1 C.Fotter County EmoU: kris8»fesopez@co||iergovoet Telephone: (239)252-8044 Administrative - Dvismn FAX: (239)252-2860 Purchasing ADDENDUM #1 Memorandum Date: November 8, 2017 From: Kristofer Lopez, Procurement Strategist To: Interested Parties Subject: Addendum #1 — 18-7239 Dredging of Wigins and Doctors Passes This addendum has been issued for the following items identifying changes, deletions, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike-through. CHANGES/ADDITIONS/DELETIONS: 1.) Technical Specifications have been uploaded If you require additional information please post a question on the Online Bidding site or contact me using the above contact information. C: Gary McAlpin, Project Manager /~~.. ~--__-, Vice President Ferreira Construction Southern Division Co., Inc. Page 1 of 1 Co ler Copinty Email: kristoferlopez@colliergov.net ~~—' -- Telephone: C%B)' 252-8944 4dnnmustrpdnoaGcxyloesDosicm F/0(�� (238)252'2880 PurchasPurchasing� ADDENDUM #2 Memorandum Date: November 9, 2017 From: Kristofer Lopez, Procurement Strategist To: Interested Parties Subject: Addendum #2— 18-7239 Dredging of Wiggins and Doctors Passes This addendum has been issued for the following items identifying changao, de|etions, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike-through. CHANGES/ADDITIONS/DELETIONS: 1.) Updated Technical Specifications have been uploaded J.) Updated Construction Time lines: --Wiggins Pass is to be completed in 120 days to Substantial Completion and 5 days for Final --Doctors Pass is to be completed in 60 days to Substantial Completion and 5 days to Final If you require additional information please post a question on the Online Bidding site or contact me using the above contact information. C: Gary McAlpin, Project Manager n Ciabattari, Vice President zFerreira Construction Southern Division Co., Inc. Paget of 2 Cm ler County Email: kristoferlopez@colliergov.net Administrative Seivices Division FAX: (239)252-2860 Purchasing ADDENDUM #3 Memorandum Date: November 16, 2017 From: Kristofer Lopez, Procurement Strategist To: Interested Parties Subject: Addendum #3— 18-7239 Dredging of Wiggins and Doctors Passes This addendum has been issued for the following items identifying changes, deletions, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike-through. CHANGES/ADDITIONS/DELETIONS: 1.) Added Contour Maps: a. Figure 5. Doctors Pass Inlet Monitoring Area Contour Map Feb 2017 b. Figure 4A:Wiggins Pass 2017 Contour Map Three-Year Monitoring Survey 2.) Answer to online Question: Reference IV TS-11 / 5.5 / iKi"Coastal navigation channel maintenance standards (62841.007(2)k) apply for nearshore disposal at Wiggins Passi-, Question IV I have seen this standard mentioned in different areas throughout the specs and permits, but have yet to see the language pertaining to this standard.Can you please provide the language to this standard or tell where it is found in the specification? Answer:This is a standard rule in Florida and paragraph (k)goes with (j),which are both included below. (j)To protect the environmental functions of Florida's beaches,only beach compatible till shall be placed on the beach or in an.y associated dune system. Beach compatible fill is material that tmiintains the general character and functionality of the material occurring on the beach and in the adjacent dune.and coastal system. Such material shall he predominately of carbonate,quartz or similar material with a particle size distribution ranging between 0,062mm(4.0)) and 4.76min( 2.25 )(classified as sand by either the Unified Soils or the Wentworth classification).shall he similar in color and grain size distribution(sand emin frequency,mean and median grain size and sorting coefficient)to the material in the existing coastal.system at the disposal site and shall not contain! 1.. Greater than 5 percent. by weight,silt,clay or colloids passing.the 4230 sieve(4.0\); 2. Greater than 5 pereent„by weight. fine gravel retained on the k.4 sieve 3. Coarse gravel.cobbles or material retained on the 34 inch sieve in a percentage or size greater than found on the native beach. 4. Construction debris,toxic material at other foreign limner:and 5 Not result in cementation of the beach. lf rocks or other non-specified materials appear on the surface Of the filled beach in excess of 50%of background in any 10.000 square foot.area,then surface rock shotIld be removed from those areas.These areas shall also be tested for Page 2 of 2 subsurface rock percentne and reinediated as required. If the natural beach exceeds any of the limiting parameters listed above.ii en the till material shall not exceed the naturally occurring level for that parameter. (k) Pursuant to subsection(t2B41.005(15), F.A.C.,sandy sedimcm derived from the maintenance of coastal navigation channels shall be deemed suitable for beach placement with up to 10%tine material passing the#230 sieve,provided that it tueet the criteria contained in j)2, through 5,above and water quality standards.if this material contains between 10%and 20%tine material passing the#230 sieve by weight,and ii meets all other sediment and water quality standards, it shall be considered suitable torr placement in the nearshote portion of the beach. If you require additional information please post a question on the Online Bidding site or contact me using the above contact information. C: Gary McAlpin, Project Manager Ackric by z . . : n Ciabattari, Vice President Ferreira Construction Southern Division Co., Inc. Page 1 of 1 Ca ler CoHnty Email: |ierQov.net Telephone: (238)252-8944 Administrative Services Division FAX: (230)252'286U p"rcbasino ADDENDUM #4 Memorandum Date: November 2O. 2017 From: Kristofer Lopez, Procurement Strategist To: Interested Parties Subject: Addendum #4— 1 8-7239 Dredging o Wiggins and Doctors Passes This addendum has been issued for the following items identifying changes, deletions, or additions to the original solicitation document and bid schedule for the subject solicitation. Changes and additions are identified with an underline and deletions have a strike-through. CHANGES/ADDITIONS/DELETIONS: 1.) Revised Bid Schedule has been attached. If you require additional information please post a question on the Online Bidding site or contact me using the above contact information. C: Gary MoA|pin. Project Manager Ackj in Ciabattan Vice President 'Ferreira Construction Southern Division Co, inc„ FERREIRA PLANT AND EQUIPMENT SCHEDULE "Lori Hill" 2016 Ellicott Draqon Series 1270 18"x18" Hydraulic Cutterhead Dredge With 35' Travelling Spud Maximum Digging Depth: 50 Feet Equipped with DredgePack Dredge Management System With Trimble Satellite System and RTK for real time tide data Water Based Support 40' x 60' x 7' Flexi Float Sectional Barge John Deere 245 Excavator Pipeline 20" SDR 17 HOPE Support/Work Boats 2016 26' Progressive Industrial Super Triumph Push Boat "Kelly McCoy" 2016 26' Progressive Industrial Super Triumph Push Boat "Rebecca Turpin" 18'Aluminum Work Boat Land Based Equipment CAT D6N Bulldozer 400 Series Excavator 2016 Komatsu WA270 Wheel Loader McElroy Pipe Fusion Machine Kawasaki ATV 100 SP Salerno Road Stualt, Florida 341997 .Phone772,286 5123. Fax 772 286 5139 www fermi!aconst'llUt1011,COM E,;%pio FERREIRA Means and Methods The scope of work proposed for the completion of the Wiggins Pass and Doctors Pass Dredging Project will be performed as indicated in the Technical Specifications and ITB Documents and in compliance with all applicable permits. Upon Notice to Proceed a Pre-Construction survey of the two (2) project areas will be performed and submitted to the Owner for evaluation and possible adjustment of the proposed dredge quantities. Just prior to actual dredging a Pre-Dredge survey will be performed and submitted to Owner to become the base line for the dredge template and used with the Post-Dredge surveys to determine the actual material removed and quantities for payment. As indicated, the Wiggins Pass dredging will be performed first, and completed, before mobilization to Doctors Pass. Upon arrival of the support barge to Wiggins Pass, pipe will be loaded on the barge and the barge pushed to a site just north of the project site and the pipe fused in 500' sections. This operation will continue until all required pipe has been fused and laid along the dredge template. Dredging will commence with the cutting of the "pilot channel" from Station 15+00 to Station -2+00 with that material being pumped to near shore Area B. Upon completion of the pilot channel, the dredge will drop back to Station 15+00 and begin the full template dredging from west to east. The spoils will now be directed to the ebb shoal Area A and that material used to form a slug to encourage flow to follow the pilot channel. Once it is determined that a sufficient amount of material is in place to "train" the channel the rest of the material will be pumped into the three marked disposal areas. Upon completion of the Wiggins Pass dredging, the dredge will be moved to Doctors Pass. The pipeline will be unbolted and towed to Doctors Pass along with the support barge. The pipeline will be reassembled and dredging will commence at Station 0+00 and work west to east through the settling basin, turning basin and into the channels. The work on the interior channels will be done during high tide due to the narrow width of the two northern channels. Once dredging is completed, demobilization and access restoration will commence. 100 SE S11,0 :Road . Stuan. Florida 34997' Phort /72285 5123 772 286 539 www,ferreiraconstruction corn -1,, ( .._ .. . .... . , ;.< i {/ . Tf! !! • \ - . -i .- . , !§ . . . . . . .... .. . .. .. ..... .!.. . : _� . !\ • • , 1i . . . . I 1 }j\ - * .° _ } ( I | ! i 1 \ƒ \ Ail {/ . • ' ( u n r1 I ,; - - I , . ,: ! ! ) !� • i/\ \ , \ \ i \ .2} ] 4Miilplri4hililiii \� 1 1 \ ^ ■-: \ 'f\ / ' a }! 5 § ) 7 ; A ?7 : ` ; ; ;: a ` ` :;:!1111 ,.. Isl ] \: / ` , j1 i!1112 , \» . } , \ /. 1111111,1! ! ;\ . > : ! ! } �� INtil !;\ - ƒ \ | / }, ' ! 1 :r\\ :• I ! ` \ \ i{[\ \ I . '{! _\ :}:!\ \ e\ . C. ) , / i \ i } ) ii 3 } ; \ } . ) \ . 2 / } . , } il } \ \ A \ -52. y I ? j )ƒ t f | E J @ ; ! I a : _ �, • • \ ! \ . # ® . . �� ! / £ : ®1 "Aa JOHN CIABATTARI VICE PRESIDENT FERREIRA. ONSTRUCTION CO.,INC. Professional Sunman! For almost 25 years, Mr. Ciabattari has been in the marine construction industry. He began his career as a captain and in 1988 transitioned to a project manager. He has supervised numerous projects and has worked as a foreman on many major New York City projects as well. He is knowledgeable and experienced in supervising all phases of construction.In addition,John has excellent communication and interpersonal skills. He is reliable and organized with an ability to work independently and as part of the team to ensure the project is completed on time and on budget.Mr.Ciabattari expertise in maritime work and construction makes him a valuable asset to the Ferreira Construction team. Professional Ferreira Construction—Southern Division 2011 -Present General.Manager- • Responsible for scheduling,personnel,equipment deployment and material procurement. • Manages cost coding of men and materials for both payroll and job costing. • Is responsible for the day to day field operations for all jobs in progress as well as pre-planning of upcoming projects. Northgate Construction Company 2004-2011 Owner • Manageda concrete and excavation company. Included duties such asadvertising,working with clients,preparing estimates, supervising, gaining permits,serving customers,and managing equipment and manpower. • Worked in accounts payable and receivable and payroll • Projects included site work and foundations for new homes and commercial projects. Pile Foundation Construction 1988—2004 Project Manager I Field Superintendent • Managed field operations for marine construction company • Partook in estimating,negotiating change orders,ordering materials and meeting with subcontractors. • Projects required moving barges, installing temporary work platforms,driving piles, installing sheeting, constructing new piers,and underpinning foundations JoKi Fishing Corporation 1984— 1988 Captain • Performed maintenance,fueling,docking and supervising crews on a 90 foot sightseeing and fishing boat. • Coordinated subcontractors, staff,advertising,accounts receivable and payable,and payroll. Private Captain 1988—2004 Captain • Captain for numerous fishing charter boats throughout the New York area. • Maintenance,fueling,docking, and supervising a crew as well as working with clients. Education and Training James Madison High School Stormwater Management Inspector CDL Class A license ERRE"' 'y", MARION "BUDDY" FRAZIER EI�;REIRA DREDGE SUPERINTEDENT CONSTRUCTION CO.,INC Professional Summary: Marion "Buddy"Frazier has more than 31 years of experience in the marine construction industry with over 19 years in job site management. His experience spans from Project Manager, Operations Manager and Dredge Captain; managing and training employees, coordinating construction requirements of contracts with sub-contractors, task training employees for OSHA and MSHA certifications and job safety. Buddy has extensive experience in job site layout, surveying, lasers,hydro-graphics,bathymetric and with dredging software to include Hy-Pack. His marine construction background also includes running day-to-day operations, quality, safety, and employee relations, as well as communications with engineers and other interpretations of drawings, design modifications and change orders. Professional Experience: Ferreira Construction Dredge Superintendent Sevenson Environmental Services Dredge Operator • Operated two dredges on Lake Onondaga in Syracuse,N.Y. under contract with Honeywell & Parsons Engineering removing contaminates from the lake. • Managed and operated Tug boat shuttling rock barges back&forth for the mechanical capping aspect of the project. Project Completion one year ahead of schedule. • Operated 1 of 5 dredges removing 5 Million cubic yards of fly ash from the Clinch River System outside of Knoxville, Tn. • Dredge Operator& Night Shift Foreman training Operators on 18"dredge on Strontia Springs Reservoir outside of Littleton, Co. digging rock&gravel, transporting it 9 miles down the mountain through 10 automated boosters systems for Denver Water in 2011. King Co. Operator/Foreman • Pulled levers on the dredge"Buxton II", completing 5 harbor projects on Lake Michigan for Detroit District,moved dredge to the Illinois River, dredging under the Rock Island Army Corp. district, and operated all other support equipment needed to set up and de- mob for United States Army Corp contracts. Southwind Construction Foreman • Operated dredges, boats, cranes,barges, and other support equipment for dredging projects under the United States Army Corp of Engineers on various projects throughout the United States, including Jupiter Inlet,FL.; Ponce Inlet, FL; Sawpit at Jacksonville/Nassau FL;Matanzas, FL; Sebastian Inlet, Lake Worth,Boynton Beach, Anna Maria Island and others throughout Florida. • Captain—24"Dredge Integrity" --Mobilized dredge and all support equipment to Mississippi for anti-flood protection projects on the Tallahatchie River, Greenwood, MS. Under Vicksburg District USACE& inspector Roble. Waste Management, Inc. Operations Manager • Estimated and attended pre-bid conferences throughout the United States for 3 years performing the following projects: • On Site Project Manager: Mocks Pond, Muncie, IN. Dredged Mocks Pond under Envirocon of hazardous waste through belt presses. Reversed the process,returning masonry sand in 3" layers, capping the remainder of 40' of hazardous material in the pond. • Project Manager: Halifax Marina dredging project for the city of Daytona Beach,FL • On-Site Manager: Dredging of the Philadelphia Marine Center of the Delaware River • On-Site Manager: Dredging of the canals in Panama City Beach, FL. Coordinated sub- contractors building seawalls and dredging of base materials for the Hibiscus Condominium Development • Project Manager: Dredging for the city of Suffolk, VA. Little Rivers Dredging Corp. President Projects include: Citadel Cement Co., Black Warrior River, Pittsburgh Midway Coal Co., Pickwick Dam Marina, and various Coal and Chemical companies R.U.S.T. International Superintendent Dredging Projects included: American Electric and Power, General Motors Corp, St. Lucie Nuclear Power Plant, Rhoune-Polenc Chemical Co, Oriental Chemical Co., City of Ocala, FL, Northern States Power Nuclear Plant, Illinois Power, and Dow Chemical Operator and Leverman on various 8"-24"dredges to include 24"dredges, "Kelly-L", "Ingenuity","Millennium","Tulsa", "Little Rock", "Dredge4", "Katrina","Dredge6", "Eloise", "Jenny", "Wilko",and "Buxton II" Certifications/Training • 2007 &2011: 40 hours Hazardous Waste Site Worker Training for Wisconsin •2005 &2011: Contractor Quality Control Management, U.S. Army Corp of Engineers • 2005: First Aid, American Heart Association • 2004-2007-2011: 8 hours Hazardous Materials Refresher Certification • 2002: Commonwealth of Virginia: Erosion and Sediment Control,Responsible Land Disturbers Certificate#14494 • 2002: JEA Safety Course(NCCER) •2002: Hazardous Materials 40 hours Training Certification S411“ FERREIRA CEBRONE ATKINS OPERATIONS MANAGER— SOUTHERN DIVISION CONSTRUCTION CO,INC. Profession al Summary Mr.Atkins has 20 years experience working with the physical forces of the coastal environment with extensive knowledge of the coastal processes such as waves,tides, currents and th.e transport of sediment. Specializing in the construction, maintenance and repair of erosion control projects,such as bulkheads, seawalls,breakwaters,revetments, groins,jetties,artificial beach nourishment,coastal bluff reshaping, vegetative stabilization and navigation projects such as docks, cribs,boat ramps and boathouses, marina basins,harbor projects and dredging. He has owned and operated marine equipment, i.e. barges,tugs, pumps and cranes in diverse situations. He has confirmable evidence of successfill completion of multi- million dollar undertakings in erosion control projects,navigation projects and harbor projects working with coordinating professionals. Professional Ferreira Construction—Southern Division 2013 -Present Dredge Operations Manager • Mr.Atkins has been recently added to the Ferreira Construction Co.,Inc. team to call upon his extensive experience and knowledge of marine construction.He will also be managing the day to day construction activities of the Southern Division. Palm Beach Marine Construction,Inc. 2005-2013 Chief Operating Officer/Vice President • Marine Contractor specializing in the permitting and construction of marinas,dredging and marine structures including docks,seawalls,rock revetments,bulkheads,etc. • Interacting with customers and other contractors. • Estimating and project management at all phases of construction. C.D.A.Construction 1998-2005 Founder and Owner • Managed the daily operations for a marine and golf course construction company. • Responsible for estimating,negotiating change orders,ordering materials and meeting with subcontractors. • Projects included multi-million dollar golf courses and marinas brought to successful completion. Murphy Construction Company 1994-1998 Superintendent and Foreman • Oversaw daily operations of on-site job construction from start to finish. • Permitting liaison ensuring environmental and structural compliance with local, state and federal agencies. • Commercial diving including bridge and seawall inspections,construction of underwater marine structures,underwater welding and use of hydraulic hand tools underwater. • Installed all forms of sheet pile from land and barge. • Dredging by both hydraulic and mechanical means. Education and Training Palm Beach State College, Lake Worth,FL General Contractor COC1517960 Stormwater Management Inspector JAMES FORRLFR RA - EFE0NRREsTRucfioNt,. DISPOSAL SITE SUPERINTENDENT Professional Summary: James Forrler has over 15 years of experience in the construction industry. His experience spans from Superintendent, Safety Officer and Equipment Operator;managing and training employees, on various safety and work place compliance issues. Professional Experience: Ferreira Construction Disposal Site Superintendent Oversee beach re-nourishment and site disposal Projects include: • Logistec Berth, Brunswick Georgia • WCI Bishop Pit, Pompano Beach, Florida • Bathtub Beach, Stuart, Florida • Jupiter Inlet, Jupiter, Florida Cavache, Inc. Superintendent Safety Officer • Responsible for all safety on DMMA. • Performed tailgate safety meetings. • Responsible for dredge tender and support equipment operations • Responsible for day to day activities which include operating boats,bulldozers, excavators,pipeline, fusing pipeline and surveying. Native Technologies, Inc. Superintendent/Safety Officer • Responsible for all safety activities. • Performed daily tailgate safety meetings. • Responsible for wetland and mitigation construction and maintenance. • Erosion control and maintenance • Equipment finish grading and operations Florida Power and Light Equipment Operator • Equipment operator and inventory control • Responsible for equipment maintenance Divosta Equipment Operator • Responsible for finish grading and surveys Toll Brothers Assistant Superintendent • Responsible for assisting site operations and managerial daily reporting Certifications/Training • OSHA 30 • CPR/First Aid • USCG Boaters Safety Course • Aquatic and Natural Area Chemical Course • USCG ABS, About Boater Safety Certification • STCW 95, Standards of Training,Certification &Watch keeping, Basic Safety Training Certification(Marine Safety) o Personal Safety& Social Responsibility MARTPT 359 o Basic Fire Fighting MARTPT—53 o Personal Survival Techniques Course MARTPT—363 • Training of High Density Polyethylene Pipe per ASTM 2620-12 • Listed Species Awareness Training—South Marco Island Beach Re-nourishment Project • Confined Space Training • Basic Hazard Training • Fall Hazard Training • Level 1 Rigging CONSTRUCTION AGREEMENT THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner") hereby contracts with Ferreira Construction Southern Division Co., Inc. ("Contractor") of 31 Tannery Road, Branchburg, NJ 08876, a Corporation, authorized to do business in the State of Florida, to perform all work ("Work") in connection with Dredging of Wiggins and Doctors Passes, Invitation to Bid No. 18-7239 ("Project"), as said Work is set forth in the Plans and Specifications prepared by Aptim Environmental & Infrastructure, Inc., the Engineer and/ or Architect of Record ("Design Professional") and other Contract Documents hereafter specified. Owner and Contractor, for the consideration herein set forth, agree as follows: Section 1. Contract Documents. A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6 hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating thereto. All of the foregoing Contract Documents are incorporated by reference and made a part of this Agreement (all of said documents including the Agreement sometimes being referred to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the Project site at all times during the performance of the Work. B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents and the appropriate number of sets of the Construction Documents, signed and sealed by the Design Professional, as are reasonably necessary for permitting. Section 2. Scope of Work. Contractor agrees to furnish and pay for all management, supervision,financing, labor, materials, tools, fuel, supplies, utilities, equipment and services of every kind and type necessary to diligently, timely, and fully perform and complete in a good and workmanlike manner the Work required by the Contract Documents. Section 3. Contract Amount. In consideration of the faithful performance by Contractor of the covenants in this Agreement to the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to Contractor the following amount (herein "Contract Amount"), in accordance with the terms of this Agreement: Two Million Ninety-Eight Thousand Nine Hundred Eighty Dollars ($2,098,980.00) Section 4. Bonds. A. Contractor shall provide Performance and Payment Bonds, in the form prescribed in Exhibit A, in the amount of 100% of the Contract Amount, the costs of which are to be paid by Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however, the surety shall meet the requirements of the Department of the Treasury Fiscal Service, "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at www.fms.treas.gov/c570/c570.html#certified. Should the Contract Amount be less than 27 Construction Services Agreement:Revised 06152017 $500,000,the requirements of Section 287.0935, F.S. shall govern the rating and classification of the surety. B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated in the State of Florida,or it ceases to meet the requirements imposed by the Contract Documents, the Contractor shall,within five(5)calendar days thereafter, substitute at its cost and expense another bond and surety, both of which shall be subject to the Owner's approval. Section 5. Contract Time and Liquidated Damages. A. Time of Performance. Time is of the essence in the performance of the Work under this Agreement. The "Commencement Date" shall be established in the written Notice to Proceed to be issued by the Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5) calendar days from the Commencement Date. No Work shall be performed at the Project site prior to the Commencement Date. Any Work performed by Contractor prior to the Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve Substantial Completion within one hundred and twenty (120) calendar days for Wiggins Pass and sixty (60) days for Doctors Pass from the Commencement Date (herein "Contract Time"). The date of Substantial Completion of the Work (or designated portions thereof) is the date certified by the Design Professional when construction is sufficiently complete, in accordance with the Contract Documents, so Owner can occupy or utilize the Work (or designated portions thereof) for the use for which it is intended. Contractor shall achieve Final Completion within five (5) calendar days for Wiggins Pass and five (5) calendar days for Doctors Pass after the date of Substantial Completion. Final Completion shall occur when the Agreement is completed in its entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the Owner's duly authorized representative and shall mean the Division Administrator or Department Director, as applicable, acting directly or through duly authorized representatives. B. Liquidated Damages in General. Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner will suffer financial loss if Contractor fails to achieve Substantial Completion within the time specified above, as said time may be adjusted as provided for herein. In such event, the total amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. Should Contractor fail to achieve Substantial Completion within the number of calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but not as a penalty, Two Thousand Five Hundred ($2,500) for each calendar day thereafter until Substantial Completion is achieved. Further, in the event Substantial Completion is reached, but the Contractor fails to reach Final Completion within the required time period, Owner shall also be entitled to assess and Contractor shall be liable for all actual damages incurred by Owner as a result of Contractor failing to timely achieve Final Completion. The Project shall be deemed to be substantially completed on the date the Project Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes any right which it may have to seek to characterize the above noted liquidated damages as a penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual damages at the time of contracting if Contractor fails to Substantially or Finally Complete the Work within the required time periods. C. Computation of Time Periods. When any period of time is referenced by days herein, it shall be computed to exclude the first day and include the last day of such period. If the last day of any such period falls on a Saturday 28 Construction Services Agreement:Revised 06152017 or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day shall be omitted from the computation, and the last day shall become the next succeeding day which is not a Saturday, Sunday or legal holiday. D. Determination of Number of Days of Default. For all contracts, regardless of whether the Contract Time is stipulated in calendar days or working days, the Owner will count default days in calendar days. E. Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions. F. Completion of Work by Owner. In the event Contractor defaults on any of its obligations under the Agreement and Owner elects to complete the Work, in whole or in part, through another contractor or its own forces, the Contractor and its surety shall continue to be liable for the liquidated damages under the Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not charge liquidated damages for any delay in achieving Substantial or Final Completion as a result of any unreasonable action or delay on the part of the Owner. G. Final Acceptance by Owner. The Owner shall consider the Agreement complete when the Contractor has completed in its entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor in writing that the Work is complete. Once the Owner has approved and accepted the Work, Contractor shall be entitled to final payment in accordance with the terms of the Contract Documents. H. Recovery of Damages Suffered by Third Parties. Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a result of Contractor's failure to fulfill all of its obligations under the Contract Documents. Owner's recovery of any delay related damages under this Agreement through the liquidated damages does not preclude Owner from recovering from Contractor any other non-delay related damages that may be owed to it arising out of or relating to this Agreement. Section 6. Exhibits Incorporated. Exhibits Incorporated: The following documents are expressly agreed to be incorporated by reference and made a part of this Agreement for Solicitation 18-7239 Dredging of Wiggins and Doctors Passes. Exhibit A: Performance and Payment Bond Forms Exhibit B: Insurance Requirements Exhibit C: Release and Affidavit Form Exhibit D: Contractor Application for Payment Form Exhibit E: Change Order Form Exhibit F: Certificate of Substantial Completion Form Exhibit G: Final Payment Checklist Exhibit H: General Terms and Conditions 29 Construction Services Agreement:Revised 06152017 Exhibit I: Supplemental Terms and Conditions Exhibit J: Technical Specifications Exhibit K: Permits Exhibit L: Standard Details(if applicable) Exhibit M: Plans and Specifications prepared by Aptim Environmental & Infrastructure, Inc. and identified as follows: Doctors Pass Technical Specs as shown on Plan Sheets 1 through 278. Exhibit N: Contractor's List of Key Personnel Section 7. Notices A. All notices required or made pursuant to this Agreement by the Contractor to the Owner shall be shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Collier County Board of County Commissioners, Florida Coastal Zone Management Section 2685 S. Horseshoe Drive, Unit 103 Naples, Florida 34104 Attention: Gary McAlpin, Project Manager Telephone: (239) 252-4245 Email: Clinton.Perrymancolliercountvfl.gov B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be made in writing and shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed to the following: Ferreira Construction Southern Division Co., Inc. 31 Tannery Road Branchburg, New Jersery 08876 Attention: John Ciabattari, Vice President Telephone: (908) 534-8655 Fax: (908) 534-8656 Email: fc(a�ferreiraconstruction.com C. Either party may change its above noted address by giving written notice to the other party in accordance with the requirements of this Section. Section 8. PUBLIC ENTITY CRIMES. 8.1 By its execution of this Contract, Construction Contractor acknowledges that it has been informed by Owner of the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity in excess of 30 Construction Services Agreement:Revised 06152017 the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." Section 9. Modification. No modification or change to the Agreement shall be valid or binding upon the parties unless in writing and executed by the party or parties intended to be bound by it. Section 10. Successors and Assigns. Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties to the Agreement. Section 11. Governing Law. The Agreement shall be interpreted under and its performance governed by the laws of the State of Florida. Section 12. No Waiver. The failure of the Owner to enforce at any time or for any period of time any one or more of the provisions of the Agreement shall not be construed to be and shall not be a waiver of any such provision or provisions or of its right thereafter to enforce each and every such provision. Section 13. Entire Agreement. Each of the parties hereto agrees and represents that the Agreement comprises the full and entire agreement between the parties affecting the Work contemplated, and no other agreement or understanding of any nature concerning the same has been entered into or will be recognized, and that all negotiations, acts, work performed, or payments made prior to the execution hereof shall be deemed merged in, integrated and superseded by the Agreement. Section 14. Severability. Should any provision of the Agreement be determined by a court to be unenforceable, such a determination shall not affect the validity or enforceability of any other section or part thereof. Section 15. Change Order Authorization. The Project Manager shall have the authority on behalf of the Owner to execute all Change Orders and Work Directive Changes to the Agreement to the extent provided for under the Owner's procurement ordinance and policies and accompanying administrative procedures. Section 16. Construction. Any doubtful or ambiguous language contained in this Agreement shall not be construed against the party who physically prepared this Agreement. The rule sometimes referred to as "fortius contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its face to have been inserted for the benefit of one of the parties shall be construed against the benefited party) shall not be applied to the construction of this Agreement. 31 Construction Services Agreement:Revised 06152017 Section 17. Order of Precedence In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Construction Agreement and the General Terms and Conditions shall take precedence over the terms of all other Contract Documents, except the terms of any Supplemental Conditions shall take precedence over the Construction Agreement and the General Terms and Conditions.To the extent any conflict in the terms of the Contract Documents including the Owner's Board approved Executive Summary cannot be resolved by application of the Supplemental Conditions, if any, or the Construction Agreement and the General Terms and Conditions, the conflict shall be resolved by imposing the more strict or costly obligation under the Contract Documents upon the Contractor at Owner's discretion. **** 32 Construction Services Agreement Revised 06152017 IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s) indicated below. CONTRACTOR: TWO WITNESSES: Ferreira Construction Southern Division Co., Inc. FIRST TNESS f 2;:t4 ttil c/4r c• Print Name chnC,GSs-H- - v . picsdenl- j/3k? Print Na nd le J Da e 1- lj A By: / I' SECOND WITNESS C-- < Print Name Dater 6 )\i( 1.~ 2/3r6/ OWNER: ATTEST: BOARD OF COU COMMISSION OF - COLLIER COU Y F i-IDA � . hE. Bra. � ef.. BY: _ �Ir ..aiil�l� BY: A pir ndy Solis,Chairman Attest as to Chairman'sS si ature only. Date: ,2-27- t •rov s =nd Legality: County Attorney Print Name (e) 33 Construction Services Agreement:Revised 06152017 INSTR 5506424 OR 5474 PG 2425 RECORDED 2/6/2018 12:15 PM PAGES 12 DWIGHT E. BROCK, CLERK OF THE CIRCUIT COURT, COLLIER COUNTY FLORIDA REC $103.50 4 EXHIBIT A 1:PUBLIC PAYMENT BOND Dredging of Wiggins and Doctors Passes Bond No. PRF09275658 Contract No. 18-7239 KNOW ALL MEN BY THESE PRESENTS: That Ferreira Construction Southern Division Co.,Inc. , as Principal, and Fidelity and Deposit Company of Maryland , as Surety, located at 1299 Zurich Way,Schaumbu IL 60196 (Business Address)are held and firmly bound to Collier County as Obligee in the sum of Two Million Ninety Eight Thousand Nine Hundred Eighty and 00/100---- ($ 2.098,980.00 )for the payment whereof we bind ourselves,our heirs,executors, personal representatives,successors and assigns,jointly and severally. WHEREAS,Principal has entered into a contract dated as of the 451"day of Decem6t°.c- 20 17 , with Obligee for Dredging of Wiggins and Doctors Passes,Contract#18-7239 in (a(f i<c— Co v,erf-c,f accordance with drawings and specifications, which contract is incorporated by referenoe-land made a part hereof, and is referred to herein as the Contract. THE CONDITION OF THIS BOND is that if Principal: Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor,materials or supplies,used directly or indirectly by Principal in the prosecution of the work provided for In the Contract,then this bond is void:otherwise it remains in full force. Any changes in or under the Contract and compliance or noncompliance with any formalities connected with the Contract or the changes do not affect Sureties obligation under this Bond. The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment Bond, regardless of the number of suits that may be filed by claimants. IN WITNESS WHEREOF, the above parties have executed this instrument this 22nd day of January 20 1s ,the name of each party being affixed and these presents duly signed by its under-signed representative, pursuant to authority of its governing body. 34 Canal red on Services Agreement:Revised 08152017 oR 5474 PG 2426 Signed,sealed and delivered in the presence of: PRINCIPAL yNI,A �nv _ 7T_iCJ/y Ferreira Construction Southern kU a l &Vitt IkZoir 4111da, USA er BY: 01` j• Witnesses as to Principal NAME: d_ i - t AJ�V ITS: �. P r;%� " NE*STATE OF Florida ,�b �0 COUNTY OF a+t n. w...M. The foregoing instrument was acknowledged before me this 5+4.day of FebC(a c-t`j, 20 la . by t)o h n-G ict ba+fa c-; as \Dice_ Prevd e n-t- - of Ferreira Construction Southern Division Co..Inc. , a mew Jecsey corporation, on behalf of the corporation.He/she is personally known to me OR has produced as identification and did(did not)take an oath. My Commission Expires: 2/15 /2.1 ►� (Siy �'Lof Notary) ti" % JOB H.IRELAND AME: 3 010 4'i. -Ire)a(I d :.• A MY COMMISSION#GG 013444 vs EXPIRES:February 15,2021 (Legibly Printed) ,4;geb,.e Banded Thu Notary Pubic Underwriters (AFFIX OFFICIAL SEAL) Notary Public, State of F 10 r Commission No.: G< 07 3L/L ./ ATTEST: SURETY: oss,. +d II t y Fidelity and Deposit Company of Maryland .,,.......,• `.. (Printed Name) ••• •• �� •• n ' 1299 Zurich Way o:•C C '$ w Schaumburg,IL 60196 11 M c i'`� m . `;• = siness Address maws " •'Grella ( orized Signature .� e Theresa J Foley,Attorney-In-Fack Witne- es 1rSu `ty Jacqueline Bevilacqua (Printed Name) a6 Conslructton SoMoes Agreement:Revised 06152017 OR 5474 PG 2427 Y.A.. )41 74-441 qq�� ,,eeORCc►Led '�Ul�G ` :o its`•_• „�-!!+ •4 `' Frankie Grella As Attorney in Fact t �? • "ach Power of Attorn- • •-pr Theresa J Foley \+�- "'4 f Witn=`ses Jacqueline Bevilacqua (Printed Name) `""e►,�w�� y 1299 Zurich Way Schaumburg,IL 60196 (Business Address) (516)387-1170 (Telephone Number) STATE OF New York COUNTY OF Nassau The foregoing instrument was acknowledged before me this 22nd day of January 20 18 , by Theresa J Foley as Attorney-In-Fact Of Fideli and Deposat_0ompany of Maryland Surety, on behalf of Surety. Ne/She is •ersonally known to me SR has produced -n• o did ='d not) take an oath. lII / ��' 1 My Commission Expires:04/20/2021 ,g ,_/. t04 SHARLINE R.ROGERS (Signature) NOTARY PUBLIC,State of New York No.01R06204400 Name: Sharline R Rogers Qualified in Queens County (Legibly Printed) Commission Expires April 20,2021 (AFFIX OFFICIAL SEAL) Notary Public, State of: New York Commission No.: 01R06204400 iE 38 Construction Services Agreement.Revised 05152017 OR 5474 PG 2428 EXTRACT FROM BY-LAWS OF THE COMPANIES "Article V,Section 8,Attorneys-in-Fact. The Chief Executive Officer,the President,or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company,and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto;and may with or without cause modify of revoke any such appointment or authority at any time." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY,and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate;and I do further certify that Article V,Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994,and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice-President, Secretary,or Assistant Secretary of the Company,whether made heretofore or hereafter,wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF,I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this _day of JAN 22 2018 ,20 • v nerot ea z r''* p f S 3 , ir 861AL j cegeeAg : u� 4UO ,21 Michael Bond,Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND,PLEASE SUBMIT ALL REQUIRED INFORMATION TO: :......... t•-Ji, , Zurich American Insurance Co. Y:` p., 44• tO Attn: Surety Claims .I-., 4.• tr C 1299 Zurich Way : 9.9, :Is Schaumburg,IL 60196-1056 4. ``� 1J9 .1k;p Mar yla!0 OR 5474 PG 2429 ZURICH AMERICAN INSURANCE COMPANY • COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS:That the ZURICH AMERICAN INSURANCE COMPANY,a corporation of the State of New York,the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY,a corporation of the State of Maryland,and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies"), by DAVID MCVICKER,Vice President,in pursuance of authority granted by Article V,Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute,and appoint Theresa J.FOLEY,Kevin T.WALSH,JR and Michael MARINO,all of Roslyn Heights,New York, EACH its true and lawful agent and Attorney-in-Fact,to make,execute,seal and deliver,for,and on its behalf as surety,and as its act and deed: any and all bonds and undertakings,and the execution of such bonds or undertakings in pursuance of these presents,shall be as binding upon said Companies,as fully and amply,to all intents and purposes,as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V,Section 8,of the By-Laws of said Companies,and is now in force. IN WITNESS WHEREOF,the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this 19th day of June,A.D.2017. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND • _ wQ Cups, .."?-47971,0.'a 0.1 c (34'°ti•o ii488AL es i P o va lacevs m �' ltvrr Assistant Secretary Vice President Dawn E.Brown David McVicker State of Maryland County of Baltimore On this 19th day of June,AD. 2017,before the subscriber, a Notary Public of the State of Maryland,duly commissioned and qualified,DAVID MCVICKER,Vice President,and DAWN E.BROWN,Assistant Secretary,of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument,and acknowledged the execution of same, and being by me duly sworn,deposeth and saith,that he/she is the said officer of the Company aforesaid,and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal the day and year first above written. /� (q-y,a„„�,Q • Constance A.Dunn,Notary Public My Commission Expires:July 9,2019 POA-F 093-0146 OR 5474 PG 2430 FIDELITY AND DEPOSIT COMPANY OF MARYLAND 600 Red Brook Blvd.,Suite 600,Owings Mills,MD 21117 Statement of Financial Condition As Of December 31,2016 ASSETS Stocks $ 141,903,342 I 22,845,654 Cash and Short Term Investments 3,080,053 Reinsurance Recoverable 13,996,720 Other Accounts Receivable 27,147,872 TOTAL ADMITTED ASSETS $ 208,973,641 d LIABILITIES,SURPLUS AND OTHER FUNDS Reserve for Taxes and Expenses $ 896,428 Ceded Reinsurance Premiums Payable 40,193,693 Securities Lending Collateral Liability 0 TOTAL LIABILITIES $ 41,090,121 Capital Stock,Paid Up $ 5,000,000 Surplus 162,883,521 i Surplus as regards Policyholders 167,883,520 TOTAL $ 208,973,641 Securities carried at$62,166,344 in the above statement are deposited with various states as required by law. Securities carried on the basis prescribed by the National Association of Insurance Commissioners. On the basis of market quotations for all bonds and stocks owned,the Company's total admitted assets at December 31,2016 would be$209,350,832 and surplus as regards policyholders$168,260,711. I,DENNIS F.KERRIGAN,Corporate Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the foregoing statement is a correct exhibit of •e assets and liabilities of the said Company on the 31st day of December,2016. 1 Cor,•rate Secretary State of Illinois City of Schaumburg SS: Subscribed and sworn to,before me,a Notary Public of the State of Illinois,in the City of Schaumburg,this 1"day of March,2017. � �.,,Y� V 7'r�1 . ��J ale"....- 1 ,. Notary Public :. .Tpo',. �''+�.' .��•�cCo e�•�: ## DARRYL JOINER I v : r '6989 s.• pa OFFICIAL SEAL A 6 9 Q 9 '''}4 r Notary P,bile•Slcio of Illinois +.J— S�' �, My Commission Expires February 24,2018 I „rr,rt.,r O. .., 1 1 OR 5474 PG 2431 • EXHIBIT A 2:PUBLIC PERFORMANCE BOND Dredging of Wiggins and Doctors Passes Bond No. PRF09275658 Contract No. 18-7239 KNOW ALL MEN BY THESE PRESENTS: That Ferreira Construction Southern Division Co.,Inc. , as Principal, and Fidelity and Deposit Company of Maryland , as Surety, located at 1299 Zurich Way,Schaumburg,II. 60196 (Business Address) are held and firmly bound to Collier County , as Obligee in the sum of Two Million Ninety Eight Thousand Nine Hundred Fighty and 0o!1 pp___- ($ 2,098.980.00 )for the payment whereof we bond ourselves,our heirs, executors, personal representatives, successors and assigns,jointly and severally. � WHEREAS, Principal has entered into a contract dated as of the a54-- day of DeGery?(-),o r- 20 17 , with Obligee for l Dredging of Wiggins and Doctors Passes Contract#18-7'39 in accordance with drawings and specifications, which contract is incorporated by reference and made a part hereof, and is referred to herein as the Contract. i THE CONDITION OF THIS BOND is that if Principal: I 1. Performs the Contract at the times and in the manner prescribed in the Contract; and 2, Pays Obligee any and all losses,damages,costs and attorneys'fees that Obligee sustains because of any default by Principal under the Contract, including, but not limited to, all delay ii damages,whether liquidated or actual, incurred by Obligee;and i t 3. Performs the guarantee of all work and materials furnished under the Contract for the time specified in the Contract,then this bond is void;otherwise it remains in full force. Any changes in i or under the Contract and compliance or noncompliance with any formalities connected with the 1 Contract or the changes do not affect Sureties obligation under this Bond. E The Surety,for value received, hereby stipulates and agrees that no changes, extensions of time, alterations or additions to the terms of the Contract or other work to be performed hereunder, or the specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby waive notice of any such changes, extensions of time, alterations or additions to the r terms of the Contract or to work or to the specifications. ii j This instrument shall be construed in all respects as a common law bond. It is expressly understood that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this bond. i In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of i this Performance Bond regardless of the number of suits that may be filed by Obligee. i IN WITNESS WHEREOF, the above parties have executed this instrument this 22nd day of January , 20 Is , the name of each party being affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 37 Construction Services Agreement:Revises 06152017 oR 5474 PG 2432 • Signed, sealed and delivered in the presence of: PRINCIPAL .. it Ferreira Construction Southern D' sion Co.,IQc. V �. •troch ()het BY: j�,. V r Y Witnesses as to Principal ` %, � r NAME: Jar1"J (11/9-0 A a Crj ,� ( ITS: t/. P STATE OF Florida +` : ;,.+'' COUNTY OF (vIc.,(----Kr‘ The foregoing instrument was acknowledged before me this SJtl''day of E bruc+.ccj 20 18 by t.)Ohn C iCl bGt r r as Pre cd ecs+ of Ferreira Construction Southern Division Co.,Inc. a Wear. Je c'e corporation,on behalf of the corporation. He/she is_p_tsonally known to me OR has produced as identification and did(did not)take an oath. My Commission Expires: 2/ I Cj/ •i • •►iii. wry+ .�H�r UW (Si•✓' ure) t\l, JOB .IREO • • MY COMMISSION#GG 073444 Name: L.)0 lib }-4. TC'etC nCQ, EXPIRES:February 15,2021 1.For: .0 Bonded nru Notary PuGie Underwriters (Legibly Printed) • (AFFIX OFFICIAL SEAL) Notary Public, State of: F1 C C'r G1.CC- Commission No.: && 67 4c4q is 38 Construction Services Agreement:Revised C6152017 oR 5474 PG 2433 ATTEST: G°�`Panj' ,"�• SURETY: �,, :•gip� � Fidelity and Deposit Company of Maryl l4: 01 `s (Printed Name) 10 °' 1299 Zurich Way .{3•:? � ~ Schaumburg,IL 60196 �••.•' t•-•pl:.: sin-ss Address) •.•....0....,, 11014 �__���� (Authorized Signatu,.� �i;Y.t'�(Q Theresa J Foley,Attorney-In- .ct Witnesses as to Surety Franlde Grella (Printed Name) _ILLS404i ildh , k, t`�Mi? oa of Frankie Grella As Attorney in Fact : •' a 0 5, -igttach Power of Att. e I m m Theresa J Foley Witn sse line Bevilacqua (Printed Name) ' 1299 Zurich Way ''TI a pt•� Schaumburg,IL 60196 (Business Address) (5161 387-1170 (Telephone Number) STATE OF New York COUNTY OF N,cca.. The foregoing instrument was acknowledged before me this 22nd day of January 20 18 , by Theresa J Foley ,as Attorney-In-Fact of Fidelity and Deposit Company of Maryland a S.irety Sze P46/She i. sersonally known t Vim- OR ha produ d � My Commission Expires: 04i20i2021 'I/ 'fry r( tgn re . SHARLINE R.ROGERS NOTARY PUBLIC,State of New York Name: Shazline R.Rogers No.011106204400 Qualified in Queens County (Legibly Printed) Commission Expires April 20,2021 (AFFIX OFFICIAL SEAL) Notary Public, State of: New York Commission No.: O1RO62o4100 • 39 Construction Services Agreement:Revised 06162017 EXHIBIT B: INSURANCE REQUIREMENTS The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Vendor shall procure and maintain property insurance upon the entire project, if required, to the full insurable value of the scope of work. The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property insurance provided herein,except such rights as they may have to the proceeds of such insurance. The Vendor and County shall,where appropriate, require similar waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in their contracts. Collier County shall be responsible for purchasing and maintaining its own liability insurance. Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on behalf of Collier County", or, the specific solicitation number and title. The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier County, Florida, as an additional insured as to the operations of Vendor under this solicitation and shall contain a severability of interests provisions. The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. The amounts and types of insurance coverage shall conform to the minimum requirements set forth in EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If Vendor has any self-insured retentions or deductibles under any of the below listed minimum required coverage, Vendor must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be Vendor's sole responsibility. Coverage(s) shall be maintained without interruption from the date of commencement of the Work until the date of completion and acceptance of the scope of work by the County or as specified in this solicitations whichever is longer. The Vendor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy cancellation or non-renewal on the part of the insurance carrier or the Vendor. The Vendor shall also notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverage or limits received by Vendor from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor hereunder, Vendor shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. Should at any time the Vendor not maintain the insurance coverages required herein,the County may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the Vendor for such coverages purchased. If Vendor fails to reimburse the County for such costs within thirty (30) days after demand,the County has the right to offset these costs from any amount due Vendor under this Agreement 40 Construction Services Agreement:Revised 06152017 or any other agreement between the County and Vendor. The County shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage(s) purchased or the insurance company or companies used. The decision of the County to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Contract Documents. If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of work, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County with such renewal certificate(s) shall be considered justification for the County to terminate any and all contracts. 41 Construction Services Agreement:Revised 06152017 Collier County Florida Insurance and Bonding Requirements Insurance/Bond Type Required Limits 1. ®Worker's Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government Compensation Statutory Limits and Requirements 2. ® Employer's Liability $_1,000,000_single limit per occurrence 3. ® Commercial General Bodily Injury and Property Damage Liability(Occurrence Form) patterned after the current $_1,000,000 single limit per occurrence, $2,000,000 aggregate for Bodily ISO form Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent Contractors; Products and Completed Operations and Contractual Liability. 4. ® Indemnification To the maximum extent permitted by Florida law, the Contractor/Vendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the ContractorNendor/Consultant or anyone employed or utilized by the ContractorNendor/Consultant in the performance of this Agreement. 5. ®Automobile Liability $_1,000,000_Each Occurrence; Bodily Injury& Property Damage, Owned/Non-owned/Hired; Automobile Included 6. ❑ Other insurance as ®Watercraft $ 1,000,000 Per Occurrence noted: Z United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. $ 1,000,000 Per Occurrence ® Maritime Coverage (Jones Act)shall be maintained where applicable to the completion of the work. $ 1,000,000 Per Occurrence ❑Aircraft Liability coverage shall be carried in limits of not less than$5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. $ Per Occurrence ❑ Pollution $ Per Occurrence ❑ Professional Liability $ Per claim & in the aggregate • $1,000,000 per claim and in the aggregate • $2,000,000 per claim and in the aggregate ❑ Project Professional Liability$ Per Occurrence ❑Valuable Papers Insurance $ Per Occurrence 7. ® Bid bond Shall be submitted with proposal response in the form of certified funds, cashiers' check or an irrevocable letter of credit, a cash bond posted with the 42 Construction Services Agreement:Revised 06152017 County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All checks shall be made payable to the Collier County Board of County Commissioners on a bank or trust company located in the State of Florida and insured by the Federal Deposit Insurance Corporation. 8. ® Performance and For projects in excess of$200,000, bonds shall be submitted with the executed Payment Bonds contract by Proposers receiving award, and written for 100% of the Contract award amount, the cost borne by the Proposer receiving an award. The Performance and Payment Bonds shall be underwritten by a surety authorized to do business in the State of Florida and otherwise acceptable to Owner; provided, however,the surety shall be rated as"A-"or better as to general policy holders rating and Class V or higher rating as to financial size category and the amount required shall not exceed 5% of the reported policy holders' surplus, all as reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New York 10038. 9. ® Consultant shall ensure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Consultant shall provide County with certificates of insurance meeting the required insurance provisions. 10. ® Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial General Liability where required. This insurance shall be primary and non-contributory with respect to any other insurance maintained by, or available for the benefit of, the Additional Insured and the Vendor's policy shall be endorsed accordingly. 11. ® The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read: For any and all work performed on behalf of Collier County. 12. ® Thirty (30) Days Cancellation Notice required. 10/17/17 - GG Consultant's Insurance Statement We understand the insurance requirements of these specifications and that the evidence of insurability may be required within five(5)days of the award of this solicitation. Name of Firm Ferreira Construction Co Inc dba Ferreira Construction Date Dec 15,2017 Consultant Southern Division Co Inc Signature ',, Print Name 77r+0,_, mow_ re Insurance Agency Conner Strong&Buckelew Agent Name Jim McGlynn Teiephone267-702-1376 43 Construction Services Agreement:Revised 06152017 EXHIBIT C: RELEASE AND AFFIDAVIT FORM COUNTY OF (COLLIER) STATE OF (FLORIDA) Before me, the undersigned authority, personally appeared who after being duly sworn, deposes and says: (1) In accordance with the Contract Documents and in consideration of $ to be received, ("Contractor") releases and waives for itself and it's subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the Agreement between Contractor and Owner, dated , 20 for the period from to . This partial waiver and release is conditioned upon payment of the consideration described above. It is not effective until said payment is received in paid funds. (2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a demand against any payment bond might be filed, shall be fully satisfied and paid upon Owner's payment to Contractor. (3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the performance by Contractor of the Work covered by this Release and Affidavit. (4) This Release and Affidavit is given in connection with Contractor's [monthly/final]Application for Payment No. CONTRACTOR BY: Witness ITS: President DATE: Witness [Corporate Seal] STATE OF COUNTY OF The foregoing instrument was acknowledged before me this day of , 20 by , as of , a corporation, on behalf of the corporation. He/she is personally known to me or has produced as identification and did (did not)take an oath. My Commission Expires: (Signature of Notary) NAME: (Legibly Printed) Notary Public, State of (AFFIX OFFICIAL SEAL) Commissioner No.: 44 Construction Services Agreement:Revised 06152017 EXHIBIT D: FORM OF CONTRACT APPLICATION FOR PAYMENT Payment, Schedule of Values and Stored Materials Record applications are available for download at: http://purchasinq.colliergov.net/Forms/Forms/Allltems.aspx 45 Construction Services Agreement:Revised 06152017 EXHIBIT E: CHANGE ORDER An electronic data entry form may be found at: http://bccsp01/SiteDirectory/ASD/Purchasing/Formsl/Forms/Defau lt.aspx Change Order Form Contract at: Change#: Purchase Order*: Project*: Contractor/Finn Name: Project Name: Project Manager Name Department: r iginel Conti acttWork Order Amount Original BCC Approval Da :Agenda Item# Current BCG ApproyedArsourt Last BCC Approval Date,Agenda Item# Current Contract/Work Order Amount SPP Contract Expiration Date(Master) Dollar Art tof this Change #DIV/0! Toil Change from iginaIAmount Revised ori;Order Total $ 0.00 #DIWO! Change frornCurrent BCC Approved Amount Cumulath Changes S 0.00 op Iwo! Change front CrrrentAmount Completion Date,Description of the Task(s)Change,and Rationale for the Change Notice to Prorer OriginalLast Approved Revised Date Date Completion D Date (rrachries tire charge) #ofDays Added Select Tasks p Add new task(s) [=f Delete task(s) 11 Changetask(s) p'Other/, o3on; Provide a response to the following:l_)detailed and specific exp lanationiratio nate of the requested changes)to the task(s)and I or the additional days added[if requested(;2.)why this change was not included in the original contract and 3.)describe the impact if this change is not processed. Attach additional information from tete Design:Professional aedslor Contra-Mar if needed. Prepared by: Date: (Prot Manager Name and Depatrncit) Acceptance of this Change Order shall constitute a modifidaticn to mitred/wort order identifiedabove and will tesarbiecttoall the sem e terms and canifitions as contained in the contract/work:order indicated shove,as holly as if the same were staged in this acceptance. The adjustment,if any.to the Cor/rad shall constitre a full and final settlement of any and all claims of the Contractor/Vendor f Consultant/ Design Professional arising out of or ralatexi to the change set forth herein,including claims ecu impact and delay casts. Accepted by: Date: (Contractor 1 Vendor$Consultant!Design Professional and Narne of Firm,if project applicatiei Approved by: Date: (Design Professional and Name of Fiinn,if project applicable) Approved by: Date: l(Prx,rrremert Professional T3.- q =ajt __:'r a; _Ot n�S5:_ 46 Construction Services Agreement: Revised 06152017 EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION OWNER'S Project No. Design Professional's Project No. PROJ ECT: CONTRACTOR Contract For Contract Date This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the following specified parts thereof: To OWNER And To Substantial Completion is the state in the progress of the Work when the Work (or designated portion) is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has been inspected by authorized representatives of OWNER,CONTRACTOR AND DESIGN PROFESSIONAL,and that Work is hereby declared to be substantially complete in accordance with the requirements of the Contract Documents on: DATE OF SUBSTANTIAL COMPLETION A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all the Work in accordance with the,Contract Documents. The items in the tentative list shall be completed or corrected by CONTRACTOR within days of the above date of Substantial Completion. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, insurance and warranties shall be as follows: 47 Construction Services Agreement:Revised 06152017 RESPONSIBILITIES: OWNER: CONTRACTOR The following documents are attached to and made a part of this Certificate: This certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the Contract Documents. Executed by Design Professional on , 20 Design Professional By: Type Name and Title CONTRACTOR accepts this Certificate of Substantial Completion on 20 CONTRACTOR By: Type Name and Title OWNER accepts this Certificate of Substantial Completion on , 20 OWNER By: Type Name and Title 48 Construction Services Agreement:Revised 06152017 EXHIBIT G: FINAL PAYMENT CHECKLIST Bid No.: Project No.: Date: , 20 Contractor: The following items have been secured by the for the Project known as and have been reviewed and found to comply with the requirements of the Contract Documents. Original Contract Amount: Final Contract Amount: Commencement Date: Substantial Completion Time as set forth in the Agreement: Calendar Days. Actual Date of Substantial Completion: Final Completion Time as set forth in the Agreement: Calendar Days, Actual Final Completion Date: YES NO 1. All Punch List items completed on 2. Warranties and Guarantees assigned to Owner(attach to this form). 3. Effective date of General one year warranty from Contractor is: 4. 2 copies of Operation and Maintenance manuals for equipment and system submitted (list manuals in attachment to this form). 5. As-Built drawings obtained and dated: 6. Owner personnel trained on system and equipment operation. 7. Certificate of Occupancy No.: issued on (attach to this form). 8. Certificate of Substantial Completion issued on 9. Final Payment Application and Affidavits received from Contractor on: 10. Consent of Surety received on 11. Operating Department personnel notified Project is in operating phase. 12. All Spare Parts or Special Tools provided to Owner: 13. Finished Floor Elevation Certificate provided to Owner: 14. Other: If any of the above is not applicable, indicate by N/A. If NO is checked for any of the above, attach explanation. Acknowledgments: By Contractor: (Company Name) (Signature) (Typed Name&Title) By Design Professional: (Firm Name) (Signature) (Typed Name&Title) By Owner: (Department Name) (Signature) (Name&Title) 49 Construction Services Agreement:Revised 06152017 EXHIBIT H: GENERAL TERMS-AND CONDITIONS 1. INTENT OF CONTRACT DOCUMENTS. 1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or portion thereof) to be constructed in accordance with the Contract Documents. Any work, materials or equipment that may reasonably be inferred from the Contract Documents as being required to produce the intended result shall be supplied whether or not specifically called for. When words which have a well known technical or trade meaning are used to describe work, materials or equipment, such words shall be interpreted in accordance with that meaning. Reference to standard specifications, manuals or codes of any technical society, organization or association or to the laws or regulations of any governmental authority having jurisdiction over the Project, whether such reference be specific or by implication, shall mean the latest standard specification, manual, code, law or regulation in effect at the time the Work is performed, except as may be otherwise specifically stated herein. 1.2 If before or during the performance of the Work Contractor discovers a conflict, error or discrepancy in the Contract Documents, Contractor immediately shall report same to the Project Manager in writing and before proceeding with the Work affected thereby shall obtain a written interpretation or clarification from the Project Manager; said interpretation or clarification from the Project Manager may require Contractor to consult directly with Design Professional or some other third party, as directed by Project Manager. Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to Contractor with the Contract Documents before commencing any portion of the Work. 1.3 Drawings are intended to show general arrangements, design and extent of Work and are not intended to serve as shop drawings. Specifications are separated into divisions for convenience of reference only and shall not be interpreted as establishing divisions for the Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy between or among the drawings, specifications or other Contract Document provisions, Contractor shall be required to comply with the provision which is the more restrictive or stringent requirement upon the Contractor, as determined by the Project Manager. Unless otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware, accessories, trim and other parts required in connection with any portion of the Work to make a complete, serviceable, finished and first quality installation shall be furnished and installed as part of the Work, whether or not called for by the Contract Documents. 2. INVESTIGATION AND UTILITIES. 2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying itself concerning the nature and location of the Work and the general and local conditions, and particularly, but without limitation, with respect to the following: those affecting transportation, access, disposal, handling and storage of materials; availability and quality of labor; water and electric power; availability and condition of roads; work area; living facilities; climatic conditions and seasons; physical conditions at the work-site and the project area as a whole; topography and ground surface conditions; nature and quantity of the surface materials to be encountered; subsurface conditions;equipment and facilities needed preliminary to and during performance of the Work; and all other costs associated with such performance. The failure of Contractor to acquaint itself with any applicable conditions shall not relieve Contractor from any of its responsibilities to perform under the Contract Documents, nor shall it be considered the basis for any claim for additional time or compensation. 50 Construction Services Agreement:Revised 06152017 2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility services above, upon, or under the Project site, said roadways, railways, drainage facilities and utilities being referred to in this Sub-Section 2.2 as the "Utilities". Contractor shall contact the owners of all Utilities to determine the necessity for relocating or temporarily interrupting any Utilities during the construction of the Project. Contractor shall schedule and coordinate its Work around any such relocation or temporary service interruption. Contractor shall be responsible for properly shoring, supporting and protecting all Utilities at all times during the course of the Work. The Contractor is responsible for coordinating all other utility work so as to not interfere with the prosecution of the Work (except those utilities to be coordinated by the Owner as may be expressly described elsewhere in the Contract Documents). 2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are encountered at the Project site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or(ii) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, and which reasonably should not have been discovered by Contractor as part of its scope of site investigative services required pursuant to the terms of the Contract Documents, then Contractor shall provide Owner with prompt written notice thereof before conditions are disturbed and in no event later than three (3) calendar days after first observance of such conditions. Owner and Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in Contractor's cost of, or time required for, performance of any part of the Work, Owner will acknowledge and agree to an equitable adjustment to Contractor's compensation or time for performance, or both, for such Work. If Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents or not of an unusual nature or should have been discovered by Contractor as part of its investigative services, and that no change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing, stating its reasons. Claims by Contractor in opposition to such determination by Owner must be made within seven(7) calendar days after Contractor's receipt of Owner's written determination notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of performance,the dispute resolution procedure set forth in the Contract Documents shall be complied with by the parties. 3. SCHEDULE. 3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall prepare and submit to Project Manager, for their review and approval, a progress schedule for the Project(herein"Progress Schedule"). The Progress Schedule shall relate to all Work required by the Contract Documents, and shall utilize the Critical Path method of scheduling and shall provide for expeditious and practicable execution of the Work within the Contract Time. The Progress Schedule shall indicate the dates for starting and completing the various stages of the Work. 3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly updates to the Progress Schedule shall be subject to the Project Manager's review and approval. Contractor shall submit the updates to the Progress Schedule with its monthly Applications for Payment noted below. The Project Manager's review and approval of the submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation to pay Contractor. 3.3 All work under this Agreement shall be performed in accordance with the requirements of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will generally be limited to the hours of 7 a.m. to 5 p.m., Monday through Friday. No work shall be performed outside the specified hours without the prior approval of the Project Manager. 51 Construction Services Agreement:Revised 06152017 4. PROGRESS PAYMENTS. 4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to Project Manager, for their review and approval, a schedule of values based upon the Contract Price, listing the major elements of the Work and the dollar value for each element. After its approval by the Project Manager, this schedule of values shall be used as the basis for the Contractor's monthly Applications for Payment. This schedule shall be updated and submitted each month along with a completed copy of the Application for Payment form signed by the Contractor's authorized representative and attached to the Agreement as Exhibit D. 4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to the Project Manager the list of its Subcontractors and materialmen submitted with its Bid showing the work and materials involved and the dollar amount of each subcontract and purchase order. Contractor acknowledges and agrees that any modifications to the list of Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors are subject to Owner's prior written approval. The first Application for Payment shall be submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may submit its invoice for any required Payment and Performance Bonds prior to the first Application of Payment provided that Contractor has furnished Owner certified copies of the receipts evidencing the premium paid by Contractor for the bonds. 4.3 Unless expressly approved by Owner in advance and in writing, said approval at Owner's sole discretion, Owner is not required to make any payment for materials or equipment that have not been incorporated into the Project. If payment is requested on the basis of materials and equipment not incorporated into the Project, but delivered and suitably stored at the site or at another location, and such payment and storage have been agreed to by Owner in writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other documentation warranting that the Owner has received the materials and equipment free and clear of all liens, charges, security interests and encumbrances, together with evidence that the materials and equipment are covered by appropriate property insurance and other arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and submit to Owner as part of its Application for Payment, the Stored Materials Record attached hereto and made a part hereof as Exhibit D. 4.4 Contractor shall submit six(6) copies of its monthly Application for Payment to the Project Manager or his or her designee, as directed by Owner(which designee may include the Design Professional). After the date of each Application for Payment is stamped as received and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its approval of only a portion of the requested payment, stating in writing its reasons therefore; or (3) return the Application for Payment to the Contractor indicating, in writing,the reason for refusing to approve payment. Payments of proper invoices in the amounts approved shall be processed and paid in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department respectively. 4.5 In the event of a total denial by Owner and return of the Application for Payment by the Project Manager, the Contractor may make the necessary corrections and re-submit the Application for Payment. The Owner shall, within ten (10) business days after the Application for Payment is stamped and received and after Project Manager approval of an Application for Payment, pay the Contractor the amounts so approved. 52 Construction Services Agreement:Revised 06152017 4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment request or ten percent(10%)of the portion thereof approved by the Project Managerfor payment, whichever is less. Such sum shall be accumulated and not released to Contractor until final payment is due unless otherwise agreed to by the Owner in accordance with Florida Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a schedule to periodically reduce the percentage of cumulative retainage held throughout the course of the Project schedule. Owner shall reduce the amount of the retainage withheld on each payment request subsequent to fifty percent(50%) completion subject to the guidelines set forth in Florida Statute 255.078 and as set forth in the Owner's procurement ordinance and policies. 4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of Contractor's Work. 4.8 Each Application for Payment, subsequent to the first pay application, shall be accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are then due and payable by Owner with respect to the current Application for Payment. Further, to the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a Release and Affidavit from each Subcontractor, sub-subcontractor, or supplier in the form attached as Exhibit C acknowledging that each Subcontractor, sub-subcontractor or supplier has been paid in full through the previous month's Application for Payment. The Owner shall not be required to make payment until and unless these affidavits are furnished by Contractor. 4.9 Contractor agrees and understands that funding limitations exist and that the expenditure of funds must be spread over the duration of the Project at regular intervals based on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first monthly Application for Payment, Contractor shall prepare and submit for Project Manager's review and approval, a detailed Project Funding Schedule,which shall be updated as necessary and approved by Owner to reflect approved adjustments to the Contract Amount and Contract Time. No voluntary acceleration or early completion of the Work shall modify the time of payments to Contractor as set forth in the approved Project Funding Schedule. 4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor acknowledges and agrees that in the event of a dispute concerning payments for Work performed under this Agreement, Contractor shall continue to perform the Work required of it under this Agreement pending resolution of the dispute provided that Owner continues to pay Contractor all amounts that Owner does not dispute are due and payable. 4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six(6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of"laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. 4.12 The County may, at its discretion, use VISA/MASTER card credit network as a payment vehicle for goods and/or services purchased as a part of this contract. The County may not accept any additional surcharges (credit card transaction fees) as a result of using the County's credit card for transactions relating to this solicitation 5. PAYMENTS WITHHELD. 53 Construction Services Agreement:Revised 06152017 5.1 The Project Manager may decline to approve any Application for Payment, or portions thereof, because of subsequently discovered evidence or subsequent inspections that reveal non- compliance with the Contract Documents. The Project Manager may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating probable filing of such claims; (c)failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents by Contractor. 5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Provided however, in the event of an emergency, Owner shall not be required to provide Contractor any written notice prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or non-liquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 5.3 In instances where the successful contractor may owe debts (including, but not limited to taxes or other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy these debts, the County reserves the right to off-set the amount owed to the County by applying the amount owed to the vendor or contractor for services performed of for materials delivered in association with a contract. 6. FINAL PAYMENT. 6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S. and the administrative procedures established by the County's Procurement Services Division and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an explicit condition precedent to the accrual of Contractor's right to final payment, shall have furnished Owner with a properly executed and notarized copy of the Release and Affidavit attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment and such other documentation that may be required by the Contract Documents and the Owner. Prior to release of final payment and final retainage, the Contractor's Representative and the Project Manager shall jointly complete the Final Payment Checklist, a representative copy of which is attached to this Agreement as Exhibit G. 6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all claims by Contractor against Owner arising out of this Agreement or otherwise relating to the Project, except those previously made in writing in accordance with the requirements of the Contract Documents and identified by Contractor as unsettled in its final Application for Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of damages for defective Work not discovered by the Design Professional or Project Manager at the time of final inspection. 7. SUBMITTALS AND SUBSTITUTIONS. 54 Construction Services Agreement:Revised 06152017 7.1 Contractor shall carefully examine the Contract Documents for all requirements for approval of materials to be submitted such as shop drawings, data, test results, schedules and samples. Contractor shall submit all such materials at its own expense and in such form as required by the Contract Documents in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. 7.2 Whenever materials or equipment are specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular supplier, the naming of the item is intended to establish the type, function and quality required. Unless the name is followed by words indicating that no substitution is permitted, materials or equipment of other suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow the Owner to determine that the material or equipment proposed is equivalent or equal to that named. Requests for review of substitute items of material and equipment will not be accepted by Owner from anyone other than Contractor and all such requests must be submitted by Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor. 7.3 If Contractor wishes to furnish or use a substitute item of material or equipment, Contractor shall make application to the Project Manager for acceptance thereof, certifying that the proposed substitute shall adequately perform the functions and achieve the results called for by the general design, be similar and of equal substance to that specified and be suited to the same use as that specified. The application shall state that the evaluation and acceptance of the proposed substitute will not prejudice Contractor's achievement of substantial completion on time, whether or not acceptance of the substitute for use in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for the Project) to adapt the design to the proposed substitute and whether or not incorporation or use by the substitute in connection with the Work is subject to payment of any license fee or royalty. All variations of the proposed substitute from that specified will be identified in the application and available maintenance, repair and replacement service shall be indicated. The application also shall contain an itemized estimate of all costs that will result directly or indirectly from acceptance of such substitute, including costs for redesign and claims of other contractors affected by the resulting change, all of which shall be considered by the Project Manager in evaluating the proposed substitute. The Project Manager may require Contractor to furnish at Contractor's expense additional data about the proposed substitute. 7.4 If a specific means, method,technique,sequence or procedure of construction is indicated in or required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, sequence, technique or procedure of construction acceptable to the Project Manager, if Contractor submits sufficient information to allow the Project Manager to determine that the substitute proposed is equivalent to that indicated or required by the Contract Documents. The procedures for submission to and review by the Project Manager shall be the same as those provided herein for substitute materials and equipment. 7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each proposed substitute and, if need be, to consult with the Design Professional. No substitute will be ordered, installed or utilized without the Project Manager's prior written acceptance which shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. The Project Manager will record time required by the Project Manager and the Project Manager's consultants in evaluating substitutions proposed by Contractor and making changes in the Contract Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute, Contractor shall reimburse 55 Construction Services Agreement:Revised 06152017 Owner for the charges of the Design Professional and the Design Professional's consultants for evaluating each proposed substitute. 8. DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS. 8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a format approved by the Project Manager. The daily log shall document all activities of Contractor at the Project site including, but not limited to, the following: 8.1.1 Weather conditions showing the high and low temperatures during work hours, the amount of precipitation received on the Project site, and any other weather conditions which adversely affect the Work; 8.1.2 Soil conditions which adversely affect the Work; 8.1.3 The hours of operation by Contractor's and Sub-Contractor's personnel; 8.1.4 The number of Contractor's and Sub-Contractor's personnel present and working at the Project site, by subcontract and trade; 8.1.5 All equipment present at the Project site, description of equipment use and designation of time equipment was used (specifically indicating any down time); 8.1.6 Description of Work being performed at the Project site; 8.1.7 Any unusual or special occurrences at the Project site; 8.1.8 Materials received at the Project site; 8.1.9 A list of all visitors to the Project 8.1.10 Any problems that might impact either the cost or quality of the Work or the time of performance. The daily log shall not constitute nor take the place of any notice required to be given by Contractor to Owner pursuant to the Contract Documents. 8.2 Contractor shall maintain in a safe place at the Project site one record copy of the Contract Documents, including, but not limited to, all drawings, specifications, addenda, amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written interpretations and clarifications issued by the Design Professional, in good order and annotated to show all changes made during construction. The annotated drawings shall be continuously updated by the Contractor throughout the prosecution of the Work to accurately reflect all field changes that are made to adapt the Work to field conditions, changes resulting from Change Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of piping, conduit and utility services. All buried and concealed items, both inside and outside the Project site, shall be accurately located on the annotated drawings as to depth and in relationship to not less than two (2) permanent features (e.g. interior or exterior wall faces). The annotated drawings shall be clean and all changes, corrections and dimensions shall be given in a neat and legible manner in a contrasting color. The"As-Built" record documents, together with all approved samples and a counterpart of all approved shop drawings shall be available to the Project Manager or Design Professional for reference. Upon completion of the Work and as a condition precedent to 56 Construction Services Agreement:Revised 06152017 Contractor's entitlement to final payment, these "As-Built" record documents, samples and shop drawings shall be delivered to Project Manager by Contractor for Owner. 8.3 Contractor shall keep all records and supporting documentation, which concern or relate to the Work hereunder for a minimum of five (5) years from the date of termination of this Agreement or the date the Project is completed or such longer period as may be required by law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with specifically those contractual requirements in 119.0701(2)(a)-(b) as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES,TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 9. CONTRACT TIME AND TIME EXTENSIONS. 9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and material-men, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein. 9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its 57 Construction Services Agreement:Revised 06152017 fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. 9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however,the granting of any such time extension shall not be a condition precedent to the aforementioned"No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion,as well as to claims based on late completion. 9.4 In no event shall any approval by Owner authorizing Contractor to continue performing Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver of any right or claim Owner may have against Contractor for delay damages hereunder. 10. CHANGES IN THE WORK. 10.1 Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon written order of Owner, and Owner shall not be liable to the Contractor for any increased compensation without such written order. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any alleged changes must be approved by Owner in writing prior to starting such items. Owner will not be responsible for the costs of any changes commenced without Owner's express prior written approval. Failure to obtain such prior written approval for any changes will be deemed: (i)a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that such items are in fact not a change but rather are part of the Work required of Contractor hereunder. 10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued and executed promptly after an agreement is reached between Contractor and Owner concerning the requested changes. Contractor shall promptly perform changes authorized by duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the Change Order in the manner as Owner and Contractor shall mutually agree. 10.3 If Owner and Contractor are unable to agree on a Change Order for the requested change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a written Work Directive Change. In that event, the Contract Amount and Contract Time shall be adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment determination, Contractor must make a claim pursuant to Section 11 of these General Conditions or else be deemed to have waived any claim on this matter it might otherwise have had. 10.4 In the event a requested change results in an increase to the Contract Amount,the amount of the increase shall be limited to the Contractor's reasonable direct labor and material costs and reasonable actual equipment costs as a result of the change(including allowance for labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In the event such change Work is performed by a Subcontractor, a maximum ten percent (10%) markup for all 58 Construction Services Agreement:Revised 06152017 overhead and profit for all Subcontractors' and sub-subcontractors'direct labor and material costs and actual equipment costs shall be permitted,with a maximum five percent(5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or sub-subcontractor for field and home office overhead is included in the markups noted above. Contractor's and Sub- Contractor's bond costs associated with any change order shall be included in the overhead and profit expenses and shall not be paid as a separate line item. No markup shall be placed on sales tax, shipping or subcontractor markup. 10.5 Owner shall have the right to conduct an audit of Contractor's books and records to verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with any Change Order or Work Directive Change. 10.6 The Project Manager shall have authority to order minor changes in the Work not involving an adjustment to the Contract Amount or an extension to the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes may be effected by Field Order or by other written order. Such changes shall be binding on the Contractor. 10.7 Any modifications to this Contract shall be in compliance with the County procurement ordinance and policies and Administrative Procedures in effect at the time such modifications are authorized. 11. CLAIMS AND DISPUTES. 11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time or other relief with respect to the terms of the Contract Documents. The term "Claim" also includes other disputes and matters in question between Owner and Contractor arising out of or relating to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party making the Claim. 11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-eight (48) hours from when the Contractor knew or should have known of the event giving rise to such Claim or else the Contractor shall be deemed to have waived the Claim. Written supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after the occurrence of the event, unless the Owner grants additional time in writing, or else the Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance with the provisions of Subsection 10.4. 11.3 The Contractor shall proceed diligently with its performance as directed by the Owner, regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise agreed to by the Owner in writing. Owner shall continue to make payments in accordance with the Contract Documents during the pendency of any Claim. 12. OTHER WORK. 12.1 Owner may perform other work related to the Project at the site by Owner's own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Contractor prior to starting any such other work. If Contractor believes that such performance will involve additional expense to Contractor or require additional time, Contractor shall send written notice of that fact to Owner and Design Professional within forty-eight(48)hours 59 Construction Services Agreement:Revised 06152017 of being notified of the other work. If the Contractor fails to send the above required forty-eight (48) hour notice,xtens one Contractor to the Conb acdeemed t T me or adju tment to the Cont act Amoun� may have had to seek an e 12.2 Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner's employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating or otherwise altering their work and will only cut or alter their work with the written consent of the Project Manager and the others whose work will be affected. The duties and responsibilities of Contractor under this paragraph are for the benefit of such utility owners and other Contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. 12.3 If any part of Contractor's Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to Project Manager in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Contractor's failure to report will constitute an acceptance of the other work as fit and proper for integration with Contractor's Work. 13. INDEMNIFICATION AND INSURANCE. 13.1 To the maximum extent permitted by Florida law, the ContractorNendor/Consultant shall defend, indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,damages, losses and costs, including, but not limited to, reasonable attorneys'fees and paralegals' fees, to the extent caused gligenca,yoneleemployed int orenuitil onalzed bynghel conduct of the ContractorNe /Consultanor ContractorNendor/Consultant in the performance of this Agreement. 13.2 The duty to defend under this Article 13 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, Owner and any indemnified party. The duty to defend la m being Prov dedimmediately Conpt actoon re sentation Cont actor's of a claim by any party and written nof ce of such c obligation to indemnify and defend�it is detender hminedis i by final judgment that expirationancle 13 ill survive the acton gainst the termination of this Agreement until Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 13.3 Contractor shall obtain ancarry, and in theall atimes moundts set forthits en Exhibit B to under the Agreement. Documents, insurance of the typeswith all of the terms, conditions, requirements Further, the Contractor shall at all times comply and obligations set forth under Exhibit B. 14. COMPLIANCE WITH LAWS. 14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealto, the Trench Safety Act, Chapter 553ing with taxation,worker's nFoFlorida Statutes).qual uInt f and safety (including, but not limited Contractor observes that the Contract Documents are at variance therewith,it shall promptly notify 60 Construction Services Agreement Revised 06152017 Project Manager in writing. To the extent any law, rule, regulation, code, statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this Agreement to be enforceable, such terms shall be deemed included in this Agreement. Notwithstanding anything in the Contract Documents to the contrary, it is understood and agreed that in the event of a change in any applicable laws, ordinances, rules or regulations subsequent to the date this Agreement was executed that increases the Contractor's time or cost of performance of the Work, Contractor is entitled to a Change Order for such increases, except to the extent Contractor knew or should have known of such changes prior to the date of this Agreement. 14.2 By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 14.3 Statutes and executive orders require employers to abide by the immigration laws of the United States and to employ only individuals who are eligible to work in the United States. The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet-based means of verifying employment eligibility of workers in the United States; it is not a substitute for any other employment eligibility verification requirements. The program will be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional services and construction services. Exceptions to the program: • Commodity based procurement where no services are provided. • Where the requirement for the affidavit is waived by the Board of County Commissioners Vendors/Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the vendor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the company. Vendors are also required to provide the Collier County Procurement Services Division an executed affidavit certifying they shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the BidderNendor does not comply with providing both the acceptable E- Verify evidence and the executed affidavit the bidder's/vendor's proposal may be deemed non-responsive. Additionally, vendors shall require all subcontracted vendors to use the E-Verify system for all purchases not covered under the"Exceptions to the program" clause above. For additional information regarding the Employment Eligibility Verification System (E-Verify) program visit the following website: http://www.dhs.gov/E-Verify. It shall be the vendor's responsibility to familiarize themselves with all rules and regulations governing this program. Vendor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended and with the provisions contained within this affidavit. Failure by the awarded firm(s)to comply with the laws referenced herein or the provisions of this affidavit shall constitute a breach 61 Construction Services Agreement:Revised 06152017 of the award agreement and the County shall have the discretion to unilaterally terminate said agreement immediately. 15. CLEANUP AND PROTECTIONS. 15.1 Contractor agrees to keep the Project site clean at all times of debr rubbish shall and waste a materials arising out of the Work. At the completion of the Work, Contractor well aall to all debris, rubbish and waste materials from and about the Project site, as appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 15.2 Any existing surface or subsurface improvements, including, but not limited to, pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not indicated in the Contract Documents to be removed or altered, shall be protected by Contractor from damage during the prosecution of the Work. Subject to the Section 2.3 above, any such improvements so damaged shall be restored by Contractor to the condition equal to that existing at the time of Contractor's commencement of the Work. 16. ASSIGNMENT. 16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner.Any attempt to assign or otherwise transfer this Agreement,or any past hn r in, without the Owner's consent, shall be void. If Contractor does, with approval, part 9 nee be tows ard ot oall of thert reof, it obligationsl and rere that its sponsibilities lities hat Contracund to tor haslt assudto assume med toward toward Contractor Owner. 17. PERMITS, LICENSES AND TAXES. 17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees, including license fees, permit fees, impact fees or inspection fees applicable to the Work through an internal budget transfer(s). Contractor is not responsible for paying for permits issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier County agencies sowhen the Contractor is acquiring permits. Owner will not be obligated to pay for any permits Subcontractors. 17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. 17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 18. TERMINATION FOR DEFAULT. nd h 18.1 Contractor shall be considerederminate the Agreements nof thgwho whole nt n part, as futher set default shall be considered cause for Owner to forth in this Section, if Contractor: (1) toilsto ro eeyi andthe t mely perform theContract Work aDocuments d rected bywithin e the time specified herein; or (2) p p Project Manager or as provided for in the approved Progress Schedule; or(3) performs the Work unsuitably or neglects or refuses to remove materials or to correct or replace such Work as may be rejected as unacceptable or unsuitable;suspended endeddwithintinues the a reasonabrosecutle timelafter being notified to on of the Work; or(5) fails to resume Work which has beenp 62 Construction Services Agreement Revised 06152017 do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy; or (7) allows any final judgment to stand against it unsatisfied for more than ten (10)days; or(8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially breaches any other provision of the Contract Documents. 18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines that Contractor has not remedied and cured the default(s) within seven (7) calendar days following receipt by Contractor of said written notice or such longer period of time as may be consented to by Owner in writing and in its sole discretion,then Owner,at its option,without releasing or waiving its rights and remedies against the Contractor's sureties and without prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate Contractor's right to proceed under the Agreement, in whole or in part, and take possession of all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor, take assignments of any of Contractor's subcontracts and purchase orders, and complete all or any portion of Contractor's Work by whatever means, method or agency which Owner, in its sole discretion, may choose. 18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall not be entitled to receive any further payments hereunder until after the Project is completed. All moneys expended and all of the costs, losses, damages and extra expenses, including all management, administrative and other overhead and other direct and indirect expenses(including Design Professional and attorneys' fees) or damages incurred by Owner incident to such completion, shall be deducted from the Contract Amount, and if such expenditures exceed the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on demand the full amount of such excess, including costs of collection, attorneys' fees (including appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to be paid to the Contractor or Owner, as the case may be, shall be approved by the Project Manager, upon application, and this obligation for payment shall survive termination of the Agreement. 18.4 The liability of Contractor hereunder shall extend to and include the full amount of any and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed by Owner in good faith under the belief that such payments or assumptions were necessary or required, in completing the Work and providing labor, materials, equipment, supplies, and other items therefore or re-letting the Work, and in settlement, discharge or compromise of any claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder. 18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is determined for any reason that Contractor was not in default, or that its default was excusable, or that Owner is not entitled to the remedies against Contractor provided herein,then the termination will be deemed a termination for convenience and Contractor's remedies against Owner shall be the same as and limited to those afforded Contractor under Section 19 below. 18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty (30) days after such payment is due or Owner otherwise persistently fails to fulfill some material obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure such default within fourteen (14) days of receiving written notice of same from Contractor, then Contractor may stop its performance under this Agreement until such default is cured, after giving Owner a second fourteen (14) days written notice of Contractor's intention to stop performance under the Agreement. If the Work is so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or their agents or employees or any other persons performing portions of the Work under contract with the 63 Construction Services Agreement:Revised 06152017 Contractor or any Subcontractor, the Contractor may terminate this Agreement by giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does not cure its default within fourteen(14) days after receipt of Contractor's written notice, Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the Agreement and recover from the Owner payment for Work performed through the termination date, but in no event shall Contractor be entitled to payment for Work not performed or any other damages from Owner. 19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION. 19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7) calendar days written notice to Contractor. In the event of such termination for convenience, Contractor's recovery against Owner shall be limited to that portion of the Contract Amount earned through the date of termination, together with any retainage withheld and reasonable termination expenses incurred, but Contractor shall not be entitled to any other or further recovery against Owner, including, but not limited to, damages or any anticipated profit on portions of the Work not performed. 19.2 Owner shall have the right to suspend all or any portions of the Work upon giving Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or any portion of the Work is so suspended,Contractor's sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in the Contract Documents. In no event shall the Contractor be entitled to any additional compensation or damages. Provided, however, if the ordered suspension exceeds six (6) months, the Contractor shall have the right to terminate the Agreement with respect to that portion of the Work which is subject to the ordered suspension. 20. COMPLETION. 20.1 When the entire Work (or any portion thereof designated in writing by Owner)is ready for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or such designated portion) is substantially complete. Within a reasonable time thereafter, Owner, Contractor and Design Professional shall make an inspection of the Work(or designated portion thereof) to determine the status of completion. If Owner, after conferring with the Design Professional, does not consider the Work (or designated portion) substantially complete, Project Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after conferring with the Design Professional, considers the Work (or designated portion) substantially complete, Project Manager shall prepare and deliver to Contractor a Certificate of Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or designated portion thereof) and include a tentative punch-list of items to be completed or corrected by Contractor before final payment. Owner shall have the right to exclude Contractor from the Work and Project site(or designated portion thereof) after the date of Substantial Completion,but Owner shall allow Contractor reasonable access to complete or correct items on the tentative punch-list. The Project Manager, shall coordinate with the Contractor the return of any surplus assets, including materials, supplies, and equipment. 20.2 Upon receipt of written certification by Contractor that the Work is completed in accordance with the Contract Documents and is ready for final inspection and acceptance, Project Manager and Design Professional will make such inspection and, if they find the Work acceptable and fully performed under the Contract Documents shall promptly approve ment, recommending that, on the basis of their observations and inspections, and the Contractor's certificted in accordance actat Documents, that the entiren that the Work has been balancewith . found to be dueContractor is due and payable Contra Cont 64 Construction Services Agreement:Revised 06152017 Neither the final payment nor the retainage shall become due and payable until Contractor submits: (1) Receipt of Contractor's Final Application for Payment. (2) The Release and Affidavit in the form attached as Exhibit C. (3) Consent of surety to final payment. (4) Receipt of the final payment check list. (5) If required by Owner, other data establishing payment or satisfaction of all obligations, such as receipts, releases and waivers of liens, arising out of the Contract Documents, to the extent and in such form as may be designated by Owner. Owner reserves the right to inspect the Work and make an independent determination as to the Work's acceptability, even though the Design Professional may have issued its recommendations. Unless and until the Owner is completely satisfied, neither the final payment nor the retainage shall become due and payable. 21. WARRANTY. 21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor or any subcontractors by any subcontractor or material men supplying materials, equipment or fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials and equipment furnished under the Contract Documents shall be new unless otherwise specified, and that all Work shall be of good quality, free from all defects and in conformance with the Contract Documents. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied,installed,connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one(1)year after Substantial Completion,any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. Further, in the event of an emergency, Owner may commence to correct any defective Work, without prior notice to Contractor, at Contractor's expense. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another representative of the Owner, shall conduct an inspection of the warranted work to verify compliance with the requirements of the Agreement. The Contractor's Representative shall be present at the time of inspection and shall take remedial actions to correct any deficiencies noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner, in addition to any other rights and remedies available to Owner. 22. TESTS AND INSPECTIONS. 22.1 Owner,Design Professional,their respective representatives, agents and employees, and governmental agencies with jurisdiction over the Project shall have access at all times to the Work, whether the Work is being performed on or off of the Project site, for their observation, inspection and testing. Contractor shall provide proper, safe conditions for such access. Contractor shall provide Project Manager with timely notice of readiness of the Work for all required inspections, tests or approvals. 65 Construction Services Agreement:Revised 06152017 22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish Project Manager the required certificates of inspection,testing or approval. All inspections,tests or approvals shall be performed in a manner and by organizations acceptable to the Project Manager. 22.3 Contractor is responsible, without reimbursement from Owner, for re-inspection fees and costs; to the extent such re-inspections are due to the fault or neglect of Contractor. 22.4 If any Work that is to be inspected, tested or approved is covered without written concurrence from the Project Manager, such work must, if requested by Project Manager, be uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor has given Project Manager timely notice of Contractor's intention to cover the same and Project Manager has not acted with reasonable promptness to respond to such notice. If any Work is covered contrary to written directions from Project Manager, such Work must, if requested by Project Manager, be uncovered for Project Manager's observation and be replaced at Contractor's sole expense. 22.5 The Owner shall charge to Contractor and may deduct from any payments due Contractor all engineering and inspection expenses incurred by Owner in connection with any overtime work. Such overtime work consisting of any work during the construction period beyond the regular eight(8) hour day and for any work performed on Saturday, Sunday or holidays. 22.6 Neither observations nor other actions by the Project Manager or Design Professional nor inspections, tests or approvals by others shall relieve Contractor from Contractor's obligations to perform the Work in accordance with the Contract Documents. 23. DEFECTIVE WORK. 23.1 Work not conforming to the requirements of the Contract Documents or any warranties made or assigned by Contractor to Owner shall be deemed defective Work. If required by Project Manager, Contractor shall as directed,either correct all defective Work, whether or not fabricated, installed or completed, or if the defective Work has been rejected by Project Manager, remove it from the site and replace it with non-defective Work. Contractor shall bear all direct, indirect and consequential costs of such correction or removal (including, but not limited to fees and charges of engineers, architects, attorneys and other professionals) made necessary thereby, and shall hold Owner harmless for same. 23.2 If the Project Manager considers it necessary or advisable that covered Work be observed by Design Professional or inspected or tested by others and such Work is not otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall uncover, expose or otherwise make available for observation, inspection or tests as Project Manager may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall bear all direct, indirect and consequential costs of such uncovering, exposure, observation, inspection and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of engineers, architects, attorneys and other professionals), and Owner shall be entitled to an appropriate decrease in the Contract Amount. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection, testing and reconstruction. 66 Construction Services Agreement:Revised 06152017 23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled workers, suitable materials or equipment or fails to finish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Project Manager may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for Owner's benefit and nothing herein shall be construed as obligating the Project Manager to exercise this right for the benefit of Design Engineer, Contractor, or any other person. 23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and consequential costs attributable to the Owner's evaluation of and determination to accept defective Work. If such determination is rendered prior to final payment, a Change Order shall be executed evidencing such acceptance of such defective Work, incorporating the necessary revisions in the Contract Documents and reflecting an appropriate decrease in the Contract Amount. If the Owner accepts such defective Work after final payment, Contractor shall promptly pay Owner an appropriate amount to adequately compensate Owner for its acceptance of the defective Work. 23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager, to correct defective Work or to remove and replace rejected defective Work as required by Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy any such deficiency. Provided, however, Owner shall not be required to give notice to Contractor in the event of an emergency. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project site, take possession of all or any part of the Work, and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Project site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Design Professional and their respective representatives, agents, and employees such access to the Project site as may be necessary to enable Owner to exercise the rights and remedies under this paragraph. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs shall include, but not be limited to, fees and charges of engineers, architects, attorneys and other professionals, all court costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner's rights and remedies hereunder. 24. SUPERVISION AND SUPERINTENDENTS. 24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be responsible to see that the finished Work complies accurately with the Contract Documents. Contractor shall keep on the Work at all times during its progress a competent resident superintendent,who shall be subject to Owner's approval and not be replaced without prior written notice to Project Manager except under extraordinary circumstances. The superintendent shall be employed by the Contractor and be the Contractor's representative at the Project site and shall have authority to act on behalf of Contractor. All communications given to 67 Construction Services Agreement:Revised 06152017 the superintendent shall be as binding as if given to the Contractor. Owner shall have the right to direct Contractor to remove and replace its Project superintendent, with or without cause. Attached to the Agreement as Exhibit N is a list identifying Contractor's Project Superintendent and all of Contractor's key personnel who are assigned to the Project; such identified personnel shall not be removed without Owner's prior written approval, and if so removed must be immediately replaced with a person acceptable to Owner. 24.2 Contractor shall have a competent superintendent on the project at all times whenever contractor's work crews, or work crews of other parties authorized by the Project Manager are engaged in any activity whatsoever associated with the Project. Should the Contractor fail to comply with the above condition, the Project Manager shall, at his discretion, deduct from the Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of adequate project supervision, not as a penalty, but as liquidated damages, separate from the liquidated damages described in Section 5.B, for services not rendered. 25. PROTECTION OF WORK. 25.1 'Contractor shall immediately notify Project Manager and Design Professional. The Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 26. EMERGENCIES. 26.1 In the event of an emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner or Design Professional is obligated to act to prevent threatened damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight(48) hours after Contractor knew or should have known of the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Project Manager determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a Change Order shall be issued to document the consequences of the changes or variations. If Contractor fails to provide the forty-eight(48)hour written notice noted above,the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 27. USE OF PREMISES. 27.1 Contractor shall maintain all construction equipment, the storage of materials and equipment and the operations of workers to the Project site and land and areas identified in and permitted by the Contract Documents and other lands and areas permitted by law, rights of way, permits and easements, and shall not unreasonably encumber the Project site with construction equipment or other material or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or any land or areas contiguous thereto, resulting from the performance of the Work. 28. SAFETY. 28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 68 Construction Services Agreement:Revised 06152017 28.1.1 All employees on or about the project site and other persons and/or organizations who may be affected thereby; 28.1.2 All the Work and materials and equipment to be incorporated therein, whether in storage on or off the Project site; and 28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs, walks, pavements, roadways, structures, utilities and any underground structures or improvements not designated for removal, relocation or replacement in the Contract Documents. 28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and regulations of any public body having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. Contractor shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of underground structures and improvements and utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation or replacement of their property. Contractor's duties and responsibilities for the safety and protection of the Work shall continue until such time as the Work is completed and final acceptance of same by Owner has occurred. All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device Coordination and Arc Flash Studies where relevant as determined by the engineer. All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE Protective labels. 28.3. Contractor shall designate a responsible representative located on a full time basis at the Project site whose duty shall be the prevention of accidents. This person shall be Contractor's superintendent unless otherwise designated in writing by Contractor to Owner. 28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property. All employees of Contractor, as well as those of all subcontractors and those of any other person or entity for whom Contractor is legally liable (collectively referred to herein as "Employees"), shall not possess or be under the influence of any such substances while on any Owner property. Further, Employees shall not bring on to any Owner property any gun, rifle or other firearm, or explosives of any kind. 28.5 Contractor acknowledges that the Work may be progressing on a Project site which is located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply with the following: 28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited; 28.5.2 All Employees shall be provided an identification badge by Contractor. Such identification badge must be prominently displayed on the outside of the Employees' clothing at all times. All Employees working at the Project site must log in and out with the Contractor each day; 28.5.3 Contractor shall strictly limit its operations to the designated work areas and shall not permit any Employees to enter any other portions of Owner's property without Owner's expressed prior written consent; 69 Construction Services Agreement:Revised 06152017 28.5.4 All Employees are prohibited from distributing any papers or other materials upon Owner's property, and are strictly prohibited from using any of Owner's telephones or other office equipment; 28.5.5 All Employees shall at all times comply with the OSHA regulations with respect to dress and conduct at the Project site. Further, all Employees shall comply with the dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations may be changed from time to time; 28.5.6 All Employees shall enter and leave Owner's facilities only through the ingress and egress points identified in the site utilization plan approved by Owner or as otherwise designated, from time to time, by Owner in writing; 28.5.7 When requested, Contractor shall cooperate with any ongoing Owner investigation involving personal injury, economic loss or damage to Owner's facilities or personal property therein; 28.5.8 The Employees may not solicit, distribute or sell products while on Owner's property. Friends, family members or other visitors of the Employees are not permitted on Owner's property; and 28.5.9 At all times, Contractor shall adhere to Owner's safety and security regulations, and shall comply with all security requirements at Owner's facilities, as said regulations and requirements may be modified or changed by Owner from time to time. 29. PROJECT MEETINGS. Prior to the commencement of Work, the Contractor shall attend a pre-construction conference with the Project Manager, Design Professional and others as appropriate to discuss the Progress Schedule, procedures for handling shop drawings and other submittals, and for processing Applications for Payment, and to establish a working understanding among the parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and all meetings convened by the Project Manager with respect to the Project, when directed to do so by Project Manager or Design Professional. The Contractor shall have its subcontractors and suppliers attend all such meetings (including the pre-construction conference) as may be directed by the Project Manager. 30. VENDOR PERFORMANCE EVALUATION. Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in excess of $25,000. To this end, vendors will be evaluated on their performance upon completion/termination of this Agreement. 31. MAINTENANCE OF TRAFFIC POLICY. For all projects that are conducted within a Collier County Right-of-Way, the Contractor shall provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On Uniform Traffic Control Devices(MUTCD),where applicable on local roadways and as prescribed in the Florida Department of Transportation's Design Standards (DS), where applicable on state roadways. These projects shall also comply with Collier County's Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available through Risk Management and/or Procurement Services Division, and is available on-line at colliergov.net/purchasing. 70 Construction Services Agreement:Revised 06152017 The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT Roadway &Traffic Design Standards Indexes, or other related documents, so to become familiar with their requirements. Strict adherence to the requirements of the Maintenance of Traffic ("MOT") policy will be enforced under this Contract. All costs associated with the Maintenance of Traffic shall be included on the line item on the bid page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of Award. 32. SALES TAX SAVINGS AND DIRECT PURCHASE. 32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to Owner, Contractor shall comply with and fully implement the sales tax savings program with respect to the Work, as set forth in section 32.2 below: 32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales tax and may wish to generate sales tax savings for the Project, Owner reserves the right to make direct purchases of various construction materials and equipment included in the Work ("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two weeks for execution of all such purchase orders by Owner. Contractor represents and warrants that it will use its best efforts to cooperate with Owner in implementing this sales tax savings program in order to maximize cost savings for the Project. Adjustments to the Contract Amount will be made by appropriate Change Orders for the amounts of each Owner Direct Purchase, plus the saved sales taxes. A Change Order shall be processed promptly after each Direct Purchase, or group of similar or related Direct Purchases, unless otherwise mutually agreed upon between Owner and Contractor. With respect to all Direct Purchases by Owner, Contractor shall remain responsible for coordinating, ordering, inspecting, accepting delivery, storing, handling, installing, warranting and quality control for all Direct Purchases. Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees that all Direct Purchases shall be included within and covered by Contractor's warranty to Owner to the same extent as all other warranties provided by Contractor pursuant to the terms of the Contract Documents. In the event Owner makes a demand against Contractor with respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer or supplier of such Direct Purchase, upon request from Contractor Owner shall un or supplier rany of any sduchlwarranties and Contract Direct Purchase by Owner. Owner may have from any manufacturer 32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes. 33. SUBCONTRACTS. 33.1 Contractor shall review the design and shall determine how it desires to divide the sequence of construction activities. Contractor will determine the breakdown and composition of bid packages for award of subcontracts, based on the current Project Milestone Schedule, and shall supply a copy of that breakdown and composition to Owner and Design Professional for their review and approval prior to submitting its first Application for Payment. Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions,availability of labor and materials, community relations and any other factors pertinent to saving time and costs. 71 Construction Services Agreement:Revised 06152017 33.2 A Subcontractor is any person or entity who is performing, furnishing, supplying or providing any portion of the Work pursuant to a contract with Contractor. Contractor shall be solely responsible for and have control over the Subcontractors. Contractor shall negotiate all Change Orders, Work Directive Changes, Field Orders and Requests for Proposal, with all affected Subcontractors and shall review the costs of those proposals and advise Owner and Design Professional of their validity and reasonableness, acting in Owner's best interest, prior to requesting approval of any Change Order from Owner. All Subcontractors performing any portion of the Work on this Project must be "qualified" as defined in Collier County Ordinance 2013-69, meaning a person or entity that has the capability in all respects to perform fully the Agreement requirements with respect to its portion of the Work and has the integrity and reliability to assure good faith performance. 33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by Owner, Contractor also shall identify any other Subcontractors, including their addresses, licensing information and phone numbers, it intends to utilize for the Project prior to entering into any subcontract or purchase order and prior to the Subcontractor commencing any work on the Project.The list identifying each Subcontractor cannot be modified,changed, or amended without prior written approval from Owner. Any and all Subcontractor work to be self-performed by Contractor must be approved in writing by Owner in its sole discretion prior to commencement of such work. Contractor shall continuously update that Subcontractor list, so that it remains current and accurate throughout the entire performance of the Work. 33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for every Subcontractor and sub-subcontractor performing any portion of the Work, as well as maintain a log of all such licenses. All subcontracts and purchase orders between Contractor and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner by the terms of the Contract Documents, as those terms may apply to the portion of the Work to be performed by the Subcontractor, (2) provide for the assignment of the subcontract or purchase order from Contractor to Owner at the election of Owner upon termination of Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or purchase order, (4) provide that Owner, Collier County Government, will be an additional insured on all liability insurance policies required to be provided by the Subcontractor except workman's compensation and business automobile policies, (5) assign all warranties directly to Owner, and (6) identify Owner as an intended third-party beneficiary of the subcontract or purchase order. Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract, copies of the Contract Documents to which the Subcontractor will be bound. Each Subcontractor shall similarly make copies of such documents available to its sub-subcontractors. 33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on- site) supervision through a named superintendent for each trade (e.g., general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing) included in its subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified employee for scheduling direction for its portion of the Work. The supervisory employees of the Subcontractor (including field superintendent, foreman and schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent level on a similar project for at least two years within the last five years. The Subcontractor shall include a resume of experience for each employee identified by it to supervise and schedule its work. 72 Construction Services Agreement:Revised 06152017 33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase orders shall provide: 33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of the subcontract or purchase order caused by events beyond its control, including delays claimed to be le to Owner or caused by Owner basedDesign on breach hrofessional or contract oraneigl negligence, shall be an extension ofesign itsonal and contract including time. m for justments 33.6.2 In the event of a changein the work,the Subntractor's such changesliplus nomorethan in the contract sum are limited exclusively to its actual costs for 10% for overhead and profit. 33.6.3 The subcontract or purchase order, as applicable, shall require the Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies for delays and changes in the Work and thus eliminate any other remedies for claim for increase in the contract price, damages, losses or additional compensation. Further, Contractor shall require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub- subcontracts and purchase orders. 33.6.4 Each subcontract and purchase order shall require that any claims by Subcontractor for delay or additional cost must be submitted to Contractor within the time and in the manner in which Contractor must submit such claims to Owner,and that failure to comply with such conditions for giving notice and submitting claims shall result in the waiver of such claims. 34. CONSTRUCTION SERVICES. 34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all Project files and records, including, but not limited to, the following administrative records: 34.1.1 Subcontracts and Purchase Orders 34.1.2 Subcontractor Licenses 34.1.3 Shop Drawing Submittal/Approval Logs 34.1.4 Equipment Purchase/Delivery Logs 34.1.5 Contract Drawings and Specifications with Addenda 34.1.6 Warranties and Guarantees 34.1.7 Cost Accounting Records 34.1.8 Labor Costs 34.1.9 Material Costs 34.1.10 Equipment Costs 34.1.11 Cost Proposal Request 34.1.12 Payment Request Records 34.1.13 Meeting Minutes 34.1.14 Cost-Estimates 34.1.15 Bulletin Quotations 34.1.16 Lab Test Reports 34.1.17 Insurance Certificates and Bonds 34.1.18 Contract Changes 34.1.19 Permits 34.1.20 Material Purchase Delivery Logs 34.1.21 Technical Standards 34.1.22 Design Handbooks 34.1.23 "As-Built" Marked Prints 73 Construction Services Agreement:Revised 06152017 34.1.24 Operating & Maintenance Instruction 34.1.25 Daily Progress Reports 34.1.26 Monthly Progress Reports 34.1.27 Correspondence Files 34.1.28 Transmittal Records 34.1.29 Inspection Reports 34.1.30 Punch Lists 34.1.31 PMIS Schedule and Updates 34.1.32 Suspense (Tickler) Files of Outstanding Requirements The Project files and records shall be available at all times to Owner and Design Professional or their designees for reference, review or copying. 34.2 Contractor Presentations At the discretion of the County, the Contractor may be required to provide a brief update on the Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per contract term. Presentations shall be made in a properly advertised Public Meeting on a schedule to be determined by the County Manager or his designee. Prior to the scheduled presentation date, the Contractor shall meet with appropriate County staff to discuss the pr followingentation requirements and format. Presentations may include, but not be limited to, the information: Original contract amount, project schedule, project completion date and any changes to the aforementioned since Notice to Proceed was issued. 35. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as amended. Background checks are valid for five(5)years and the Contractor shall be responsible for all associated costs. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Division for all employees that shall provide services to the County under this Agreement.This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four(4) years. All of Contractor's employees and subcontractors must wear Collier County Government Identification badges at all times while performing services on County facilities and properties. Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed each year at no cost to the Contractor during the time period in which their background check is valid, as discussed below. All technicians shall have on their shirts the name of the contractor's business. The Contractor shall immediately notify the Collier County Facilities Management Division via e- mail (DL-FMOPSAcolliergov.net) whenever an employee assigned to Collier County separates from their employment. This notification is critical to ensure the continued security of Collier County facilities and systems. Failure to notify within four (4) hours of separation may result in a deduction of$500 per incident. CCSO requires separate fingerprinting prior to work being performed in any of their locations. This will be coordinated upon award of the contract. If there are additional fees for this process, the vendor is responsible for all costs. 74 Construction Services Agreement:Revised 06152017 36. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exdusive jurisdiction on all such matters. 37. VALUE ENGINEERING. All projects with an estimated cost of$10 million or more shall be reviewed for consideration of a Value Engineering (VE) study conducted during project development. A"project" shall be defined as the collective contracts, which may include but not be limited to: design, construction, and construction, engineering and inspection (CEI) services. Additionally, any project with an estimated construction value of$2 million or more may be reviewed for VE at the discretion of the County. 38. ABOVEGROUND/UNDERGROUND TANKS. 38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 & 30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 &403 Florida Statutes; and STI, UL, PEI, ASME, NAGE, NLPA, NIST &API referenced standards pertaining to the storage of hazardous materials and petroleum products. 38.2 The contractor shall notify the Solid& Hazardous Waste Management Department (SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day tanks for generators, storing/will be storing petroleum products or hazardous materials. The contractor shall provide a 10 day and 48 hour notice to SHWMD 239-252-2508 prior to commencement. The contractor shall provide the plans pertaining to the storage tank systems containing hazardous materials/ petroleum products to the SHWMD prior to plans submittal to a permitting entity and then SHWMD must approve the plans prior to contractor's submittal for permitting. 39. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on Owner's projects who are neat, clean, well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The Owner may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Owner's projects is not in the best interest of the County. 40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision- making authority and by Owner's staff person who would make the presentation of any settlement reached during negotiations to Owner for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by 75 Construction Services Agreement:Revised 06152017 representatives of Contractor with full decision-making authority and by Owner's staff person or designee who would make the presentation of any settlement reached at mediation to Owner's Board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exdusive jurisdiction on all such matters. 76 Construction Services Agreement:Revised 06152017 EXHIBIT I: SUPPLEMENTAL TERMS AND CONDITIONS Supporting documents found at: http://bid.colliergov.netlbidl and titled: N/A 77 Construction Services Agreement:Revised 06152017 EXHIBIT J: TECHNICAL SPECIFICATIONS Supporting documents found at: http://bid.colliergov.net/bid/ and titled: 18-7239 Doctors Wiggins Pass Technical Specifications 78 Construction Services Agreement:Revised 06152017 EXHIBIT K: PERMITS Supporting documents found at: http://bid.colliergov.net/bid/ and titled: N/A 79 Construction Services Agreement:Revised 06152017 EXHIBIT L: STANDARD DETAILS Supporting documents found at: http://bid.colliergov.net/bid/ and titled: N/A 80 Construction Services Agreement:Revised 06152017 EXHIBIT M: PLANS AND SPECIFICATIONS Supporting documents found at: http://bid.colliergov.net/bid/ and titled: N/A 81 Construction Services Agreement:Revised 06152017 EXHIBIT N: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT Name Personnel Category Buddy Frazier Construction Superintendent Michael Ciabattari Project Manager 82 Construction Services Agreement:Revised 06152017 Client#: 353923 FERRECONST ACORDTM CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 1/05/2018 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed.If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Conner Strong&Buckelew (PIM,tet) 267402-1467 FAX 856-830-1534 Two Liberty Place E-MAIL (ac,No): ADDRESS: 50 S. 16th Street,Suite 3600 INSURER(S)AFFORDING COVERAGE NAIC# Philadelphia, PA 19102 INSURER A:Zurich American Insurance Co. 16535 INSURED INSURER B:Starr Indemnity&Liability Com 38318 Ferreira Construction Co, Inc.dba INSURER C:Navigators Insurance Co. 42307 Ferreira Construction Southern Division Great 26344 Co.,Inc.; 7120 South Kanner Highway INSURER D: Pan Suite 11 Stuart,FL 34997 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDLSUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSR WVD POLICY NUMBER (MM/DD/YYYY) (MMIDD/YYYY) LIMITS A GENERAL LIABILITY GL0019785401 07/01/2017 07/01/2018 EACH OCCURRENCE $2,000,000 X COMMERCIAL GENERAL LIABILITY PREMISES(EaE ED nce) $1,000,000 CLAIMS-MADE X OCCUR MED EXP(Any one person) _$10,000 _ PERSONAL&ADV INJURY $2,000,000 GENERAL AGGREGATE $4,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $4,000,000 7 POLICY XPRO X LOC $ JECT A AUTOMOBILE LIABILITY BAP019787301 07/01/2017 07/01/2018 COMacBciINEDdent)SINGLE LIMIT 2� , 0000 (Ea _00 X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED accident(Per BODILY INJURY $ AUTOS AUTOS ) X HIRED AUTOS X NON-OWNED PROPERTY DAMAGE $ AUTOS (Per accident) B UMBRELLA LIAB X OCCUR 1000023782 07/01/2017 07/01/2018 EACH OCCURRENCE $3,000,000 X EXCESS LIAB CLAIMS-MADE AGGREGATE $3,000,000 DED RETENTION$ $ A WORKERS COMPENSATION WC019787401 07/01/2017 07/01/2018 X WC STATU- OTH- ERAND EMPLOYERS'LIABILITY Y/N TORY LIMITS ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? N N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 C Excess Liability NY17EXC878764IV 07/01/2017 07/01/2018 $5M occ/$5M agg D Excess Liability EXC1603729 07/01/2017 07/01/2018 $17M occ/$17M agg DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(Attach ACORD 101,Additional Remarks Schedule,if more space is required) Hull and Protection&Indemnity Coverages: Carrier: Continental Insurance Company; (NAIC Number:35289) Policy Number: H877278 Policy Period:07/01/2017 to 07/01/2018 Hull&Machinery TIV:Agreed Value per schedule on policy (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION Collier County Board of County SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Commissioners Procurement ACCORDANCE WITH THE POLICY PROVISIONS. Services Division ATTN Barbara Lance 3295 Tamiami Trail E AUTHORIZED REPRESENTATIVE Naples,FL 34112 n ©1988-2010 ACORD CORPORATION.All rights reserved. ACORD 25(2010/05) 1 of 2 The ACORD name and logo are registered marks of ACORD #S1836506/M1770838 EMH DESCRIPTIONS (Continued from Page 1) P&I: $1,000,000 Per Occurrence/CSL Maritime Employers Liability: Carrier: United Specialty Insurance Company(NAIC#12537) Policy Number:TDS1006-17 Policy Period: 07/01/2017 to 07/01/2018 Limit: $1,000,000 Combined Single Limit each accident Jones Act&Longshore And Harbor Workers'Compensation Act Coverage apply where applicable. RE: FCC 4172 Contract 18-7239 Dredging of Wiggins and Doctors Passes Collier County Board of County Commissioners,or Board of County Commissioners in Collier County or Collier County Government are additional insured on a primary and non-contributory basis on the above referenced Commercial General Liability Policy if required by written contract. 1 SAGITTA 25.3(2010/05) 2 of 2 #S1836506/M1770838