Agenda 10/14/2014 Item # 16A20 10/14/2014 16.A.20.
EXECUTIVE SUMMARY
Recommendation to approve and authorize the Chairman to execute Contract No. 14-6257 to
provide professional engineering services as required by the Doctors Pass Jetty and Erosion
Control Project for $148,266 (Project No. 90029) to Humiston and Moore Engineers and make a
finding that this item promotes tourism.
OBJECTIVE: To obtain professional engineering services to engineer, design and obtain a
Notice to Proceed as required to execute the rebuild of the South Doctors Pass Jetty and Erosion
Control Project.
CONSIDERATIONS: At the June 24, 2014 BCC meeting Item 16A21, the BCC approved the
ranked list of design professions pursuant to RFP No. 14-6257, "Doctors Pass Jetty", authorizing
staff to negotiate a contract with the top ranked firm, Humiston & Moore, for subsequent Board
approval.
This project consists of professional services required to restore the south Jetty to original design
conditions and the design and permitting of an additional erosion control structure(s) to reduce
down drift beach erosion on the south side of the inlet.
The south jetty of Doctors Pass has suffered significant deterioration over the past 20+years and
requires rebuilding to the original design conditions to restore its functionality. The beach
immediately south of Doctors Pass is consistently the most severely eroded of all beaches within
the County. An erosion control structure is required to reduce the rate of sand loss from the
beaches within the influence of Doctors Pass on the down drift south side of the inlet.
FISCAL IMPACT: Funding for the proposed work order is included in the Fiscal Year 15
budget; Tourist Development Tax Fund (195) Project No. 90029, Doctors Pass S. Jetty Rebuild.
Funding for this project will not be requested for reimbursement from any grantor agency.
GROWTH MANAGEMENT IMPACT: There are no Growth Management Impacts as a result
of this project at this time.
ADVISORY COMMITTEE RECOMMENDATIONS: At the September 11, 2014 CAC
meeting this item was unanimously approved by a 7 to 0 vote.
At the September 29, 2014 Tourist Development Council (TDC) meeting this item was
unanimously approved by a 7 to 0 vote.
LEGAL CONSIDERATIONS: This item has been approved as to form and legality and
requires majority vote for approval.—CMG
RECOMMENDATION: To approve and authorize the Chairman to execute Contract No. 14-
6257 to provide professional engineering services as required by the Doctors Pass Jetty and
Erosion Control Project for $148,266 to Humiston and Moore Engineers and make a finding that
this item promotes tourism.
Packet Page -839-
10/14/2014 16.A.20.
Prepared by: J. Gary McAlpin, PE Coastal Zone Management Manager of the Natural Resources
Department
Attachments: Contract No. 14-6257
Packet Page -840-
10/14/2014 16.A.20.
COLLIER COUNTY
Board of County Commissioners
Item Number: 16.16.A.16.A.20.
Item Summary: Recommendation to approve and authorize the Chairman to execute
Contract No. 14-6257 to provide professional engineering services as required by the Doctors
Pass Jetty and Erosion Control Project for$148,266 (Project No. 90029) to Humiston and Moore
Engineers and make a finding that this item promotes tourism.
Meeting Date: 10/14/2014
Prepared By
Name: HambrightGail
Title: Accountant, Coastal Zone Management
9/17/2014 12:10:19 PM
Submitted by
Title: Accountant, Coastal Zone Management
Name: HambrightGail
9/17/2014 12:10:21 PM
Approved By
Name: PattersonAmy
Title: Manager-Impact Fees &EDC, Business Management&Budget Office
Date: 9/18/2014 9:14:05 AM
Name: McAlpinGary
Title: Manager-Coastal Management Programs, Coastal Zone Management
Date: 9/18/2014 1:54:09 PM
Name: Tara Castillo
Title: Management/Budget Analyst, Road Maintenance
Date: 9/19/2014 10:04:25 AM
Name: LorenzWilliam
Title: Director-CDES Engineering Services.Natural Resources
Date: 9/22/2014 10:42:33 AM
Packet Page -841-
10/14/2014 16.A.20.
Name: MarkiewiczJoanne
Title: Director-Purchasing/General Services, Purchasing&General Services
Date: 9/22/2014 11:13:02 AM
Name: KearnsAllison
Title: Manager Financial &Operational Support, Transportation Administration
Date: 9/22/2014 1:51:56 PM
Name: PuigJudy
Title: Operations Analyst,Community Development&Environmental Services
Date: 9/22/2014 2:54:34 PM
Name: JohnsonScott
Title: Manager-Procurement,Purchasing&General Services
Date: 9/23/2014 3:11:57 PM
Name: NorthrupAdam
Title: Procurement Specialist,Purchasing&General Services
Date: 9/25/2014 8:11:02 AM
Name: PuigJudy
Title: Operations Analyst, Community Development&Environmental Services
Date: 9/25/2014 4:46:43 PM
Name: GreeneColleen
Title: Assistant County Attorney, CAO General Services
Date: 10/7/2014 11:39:02 AM
Name: MarcellaJeanne
Title: Executive Secretary, Transportation Planning
Date: 10/7/2014 1:02:17 PM
Name: StanleyTherese
Title: Manager-Grants Compliance, Grants Management Office
Date: 10/7/2014 1:28:51 PM
Name: KlatzkowJeff
Title: County Attorney,
Date: 10/8/2014 8:33:06 AM
Name: FinnEd
Title: Management/Budget Analyst, Senior, Transportation Engineering&Construction Management
Date: 10/8/2014 11:55:16 AM
Packet Page -842-
10/14/2014 16.A.20.
Name: OchsLeo
Title: County Manager, County Managers Office
Date: 10/8/2014 2:27:35 PM
Packet Page-843-
10/14/2014 16.A.20.
Contract# 14-6257 "Engineering Services for Doctors Pass Jetty"
PROFESSIONAL SERVICES AGREEMENT
THIS AGREEMENT is made and entered into this day of , 2014 by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision
of the State of Florida (hereinafter referred to as the "COUNTY" or "OWNER") and Humiston &
Moore Engineers, P.A., authorized to do business in the State of Florida, whose business
address is 5679 Strand Court, Naples, FL 34110 (hereinafter referred to as the
"CONSULTANT").
WITNESSETH:
WHEREAS, the OWNER desires to obtain the professional Consulting services of the
CONSULTANT concerning Engineering Services for Doctors Pass Jetty (hereinafter referred
to as the "Project"), said services being more fully described in Schedule A, "Scope of
Services", which is attached hereto and incorporated herein;
WHEREAS, the CONSULTANT has submitted a proposal for provision of those services;
and
WHEREAS, the CONSULTANT represents that it has expertise in the type of
professional services that will be required for the Project.
NOW, THEREFORE, in consideration of the mutual covenants and provisions contained
herein, the parties hereto agree as follows:
ARTICLE ONE
CONSULTANT'S RESPONSIBILITY
1.1. CONSULTANT shall provide to OWNER professional Engineering Consulting services
in all phases of the Project to which this Agreement applies.
CA
[14-PRC-02738!1 1 1 0668/1] I
Packet Page -844-
10/14/2014 16.A.20.
1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the
Scope of Services described in detail in Schedule A. The total compensation to be paid
CONSULTANT by the OWNER for all Basic Services is set forth in Article Five and Schedule B,
"Basis of Compensation", which is attached hereto and incorporated herein.
1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this
Agreement all such licenses as are required to do business in the State of Florida and in Collier
County, Florida, including, but not limited to, all licenses required by the respective state boards
and other governmental agencies responsible for regulating and licensing the professional
services to be provided and performed by the CONSULTANT pursuant to this Agreement.
1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a
professional service which, under Florida Statutes, requires a license, certificate of authorization
or other form of legal entitlement to practice such services, it shall employ and/or retain only
qualified personnel to provide such services to OWNER.
1.5. CONSULTANT designates Brett D. Moore, PE, a qualified licensed professional to serve
as the CONSULTANT'S project coordinator (hereinafter referred to as the "Project
Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the
CONSULTANT with respect to directing, coordinating and administering all aspects of the
services to be provided and performed under this Agreement. Further, the Project Coordinator
has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating
to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote
whatever time is required to satisfactorily manage the services to be provided and performed by
the CONSULTANT hereunder. The Project Coordinator shall not be removed by
CONSULTANT from the Project without OWNER'S prior written approval, and if so removed
must be immediately replaced with a person acceptable to OWNER.
[14-PRC-02738/1 1 1 0668/11
Packet Page -845-
.
10/14/2014 16.A.20.
1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request
from Owner to promptly remove and replace the Project Coordinator, or any other personnel
employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any
personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to
provide and perform services or work pursuant to the requirements of this Agreement, said
request may be made with or without cause. Any personnel so removed must be immediately
replaced with a person acceptable to OWNER.
1.7. The CONSULTANT represents to the OWNER that it has expertise in the type of
professional services that will be performed pursuant to this Agreement and has extensive
experience with projects similar to the Project required hereunder. The CONSULTANT agrees
that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to
the OWNER'S review and approval and shall be in accordance with the generally accepted
standards of professional practice in the State of Florida, as well as in accordance with all
applicable laws, statutes, including but not limited to the Local Government Prompt Payment Act
(218.735 and 218.76 F.S.), as amended, the Florida Public Records Law Chapter 119 (including
specifically those contractual requirements at F.S. § 119.0701(2)(a)-(d) and (3)), ordinances,
codes, rules, regulations and requirements of any governmental agencies, and the Florida
Building Code where applicable, which regulate or have jurisdiction over the Project or the
services to be provided and performed by CONSULTANT hereunder. In the event of any
conflicts in these requirements, the CONSULTANT shall notify the OWNER of such conflict and
utilize its best professional judgment to advise OWNER regarding resolution of each such
conflict. OWNER'S approval of the design documents in no way relieves CONSULTANT of its
obligation to deliver complete and accurate documents necessary for successful construction of
the Project.
1.7.1 The County reserves the right to deduct portions of the (monthly) invoiced (task)
amount for the following: Tasks not completed within the expressed time frame, including
required deliverables, incomplete and/or deficient documents, failure to comply with local, state
[14-PRC-02738/1110668/1] 3 C q0
Packet Page -846-
10/14/2014 16.A.20.
and/or federal requirements and/or codes and ordinances applicable to Consultant's
performance of the work as related to the project. This list is not deemed to be all-inclusive, and
the County reserves the right to make sole determination regarding deductions. After notification
of deficiency, if the Consultant fails to correct the deficiency within the specified timeframe,
these funds would be forfeited by the Consultant. The County may also deduct or charge the
Consultant for services and/or items necessary to correct the deficiencies directly related to the
Consultant's non-performance whether or not the County obtained substitute performance.
1.8. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm
or organization, without OWNER'S prior written consent, or unless incident to the proper
performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or
legislative proceedings where such information has been properly subpoenaed, any non-public
information concerning the services to be rendered by CONSULTANT hereunder, and
CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to
comply with the provisions of this paragraph. CONSULTANT shall provide OWNER prompt
written notice of any such subpoenas.
1.9 As directed by OWNER, all plans and drawings referencing a specific geographic area
must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in
the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should
either reference specific established Survey Monumentation, such as Certified Section Corners
(Half or Quarter Sections are also acceptable), or when implemented, derived from the
RTK(Real-Time Kinematic) GPS Network as provided by OWNER. Information layers shall have
common naming conventions (i.e. right-of-way - ROW, centerlines - CL, edge-of-pavement-
EOP, etc), and adhere to industry standard CAD specifications.
[l 4-PRC-0273 811 I 10668/11 4 C�
Packet Page -847-
10/14/2014 16.A.20.
ARTICLE TWO
ADDITIONAL SERVICES OF CONSULTANT
If authorized in writing by OWNER through a Change Order to this Agreement, CONSULTANT
shall furnish or obtain from others Additional Services of the types listed in Article Two herein.
The agreed upon scope, compensation and schedule for Additional Services shall be set forth in
the Amendment authorizing those Additional Services. With respect to the individuals with
authority to authorize Additional Services under this Agreement, such authority will be as
established in OWNER'S Purchasing Ordinance and Procedures in effect at the time such
services are authorized. These services will be paid for by OWNER as indicated in Article Five
and Schedule B. Except in an emergency endangering life or property, any Additional Services
must be approved in writing via an Amendment to this Agreement prior to starting such services.
OWNER will not be responsible for the costs of Additional Services commenced without such
express prior written approval. Failure to obtain such prior written approval for Additional
Services will be deemed: (i) a waiver of any claim by CONSULTANT for such Additional
Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a
part of the Basic Services required of CONSULTANT hereunder. If OWNER determines that a
change in the Agreement is required because of the action taken by CONSULTANT in response
to an emergency, an Amendment shall be issued to document the consequences of the
changes or variations, provided that CONSULTANT has delivered written notice to OWNER of
the emergency within forty-eight (48) hours from when CONSULTANT knew or should have
known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above,
waives CONSULTANT'S right it otherwise may have had to seek an adjustment to its
compensation or time of performance under this Agreement. The following services, if not
otherwise specified in Schedule A as part of Basic Services, shall be Additional Services:
2.1. Preparation of applications and supporting documents (except those already to be
furnished under this Agreement) for private or governmental grants, loans, bond issues or
advances in connection with the Project.
[14-PRC-02738/1110668/1] 5
Packet Page -848-
10/14/2014 16.A.20.
2.2. Services resulting from significant changes in the general scope, extent or character of
the Project or its design including, but not limited to, changes in size, complexity, OWNER'S
schedule or character of construction; and revising studies, reports, design documents or
Contract Documents previously accepted by OWNER when such revisions are required by
changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not
reasonably anticipated prior to the preparation of such studies, reports or documents, or are due
to any other causes beyond CONSULTANT'S control and fault.
2.3 Providing renderings or models for OWNER'S use.
2.4 Investigations and studies involving detailed consideration of operations, maintenance
and overhead expenses; the preparation of feasibility studies, cash flow and economic
evaluations, rate schedules and appraisals; and evaluating processes available for licensing and
assisting OWNER in obtaining such process licensing.
2.5. Furnishing services of independent professional associates and consultants for other
than the Basic Services to be provided by CONSULTANT hereunder.
2.6. Services during travel outside of Collier and Lee Counties required of CONSULTANT and
directed by OWNER, other than visits to the Project site or OWNER's office.
2.7 Preparation of operating, maintenance and staffing manuals, except as otherwise
provided for herein.
2.8. Preparing to serve or serving as a CONSULTANT or witness for OWNER in any litigation,
or other legal or administrative proceeding, involving the Project (except for assistance in
consultations which are included as part of the Basic Services to be provided herein).
CA
[14-PRC-02738/1 1 1 066811] 6
Packet Page -849-
10/14/2014 16.A.20.
2.9 Additional services rendered by CONSULTANT in connection with the Project, not
otherwise provided for in this Agreement or not customarily furnished in Collier County as part of
the Basic Services in accordance with generally accepted professional practice.
ARTICLE THREE
OWNER'S RESPONSIBILITIES
3.1. The OWNER shall designate in writing a project manager to act as OWNER'S
representative with respect to the services to be rendered under this Agreement (hereinafter
referred to as the "Project Manager"). The Project Manager shall have authority to transmit
instructions, receive information, interpret and define OWNER'S policies and decisions with
respect to CONSULTANT'S services for the Project. However, the Project Manager is not
authorized to issue any verbal or written orders or instructions to the CONSULTANT that would
have the effect, or be interpreted to have the effect, of modifying or changing in any way
whatever:
(a) The scope of services to be provided and performed by the CONSULTANT
hereunder;
(b) The time the CONSULTANT is obligated to commence and complete all such
services; or
(c) The amount of compensation the OWNER is obligated or committed to pay the
CONSULTANT.
3.2. The Project Manager shall:
(a) Review and make appropriate recommendations on all requests submitted by
the CONSULTANT for payment for services and work provided and performed
in accordance with this Agreement;
(b) Provide all criteria and information requested by CONSULTANT as to OWNER's
requirements for the Project, including design objectives and constraints,
space, capacity and performance requirements, flexibility and expandability,
and any budgetary limitations;
C.A
[14-PRC-02738/1110668/1] 7
Packet Page -850-
10/14/2014 16.A.20.
(c) Upon request from CONSULTANT, assist CONSULTANT by placing at
CONSULTANT'S disposal all available information in the OWNER'S
possession pertinent to the Project, including existing drawings, specifications,
shop drawings, product literature, previous reports and any other data relative
to the Project;
(d) Arrange for access to and make all provisions for CONSULTANT to enter the
Project site to perform the services to be provided by CONSULTANT under this
Agreement; and
(e) Provide notice to CONSULTANT of any deficiencies or defects discovered by
the OWNER with respect to the services to be rendered by CONSULTANT
hereunder.
ARTICLE FOUR
TIME
4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the
execution of this Agreement upon written Notice to Proceed from OWNER for all or any
designated portion of the Project and shall be performed and completed in accordance with the
Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of
the essence with respect to the performance of this Agreement.
4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its
services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due
to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts
of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or
lock-outs, then CONSULTANT shall notify OWNER in writing within five (5) working days after
commencement of such delay, stating the specific cause or causes thereof, or be deemed to
have waived any right which CONSULTANT may have had to request a time extension for that
specific delay.
[14-PRC-0273811 1 1 0668/1] 8 CA
Packet Page -851-
10/14/2014 16.A.20.
4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of CONSULTANT'S services from any cause whatsoever, including those for which
OWNER may be responsible in whole or in part, shall relieve CONSULTANT of its duty to
perform or give rise to any right to damages or additional compensation from OWNER.
CONSULTANT'S sole remedy against OWNER will be the right to seek an extension of time to
its schedule provided, however, the granting of any such time extension shall not be a condition
precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall
expressly apply to claims for early completion, as well as claims based on late completion.
Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided
hereunder have been delayed for a total of 180 calendar days, CONSULTANT'S compensation
shall be equitably adjusted, with respect to those services that have not yet been performed, to
reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of
such delays.
4.4 Should the CONSULTANT fail to commence, provide, perform or complete any of the
services to be provided hereunder in a timely manner, in addition to any other rights or remedies
available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold
any and all payments due and owing to the CONSULTANT until such time as the
CONSULTANT resumes performance of its obligations hereunder in such a manner so as to
reasonably establish to the OWNER's satisfaction that the CONSULTANT'S performance is or
will shortly be back on schedule.
4.5 In no event shall any approval by OWNER authorizing CONSULTANT to continue
performing Work under this Agreement or any payment issued by OWNER to CONSULTANT be
deemed a waiver of any right or claim OWNER may have against CONSULTANT for delay or
any other damages hereunder.
[14-PRC-02738/1110668/1 j 9 C.A
Packet Page -852-
10/14/2014 16.A.20.
ARTICLE FIVE
COMPENSATION
5.1. Compensation and the manner of payment of such compensation by the OWNER for
services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled
"Basis of Compensation", which is attached hereto and made a part hereof.
ARTICLE SIX
OWNERSHIP OF DOCUMENTS
6.1. Upon the completion or termination of this Agreement, as directed by OWNER,
CONSULTANT shall deliver to OWNER copies or originals of all records, documents, drawings,
notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports
and other technical data, other than working papers, prepared or developed by or for
CONSULTANT under this Agreement ("Project Documents"). OWNER shall specify whether
the originals or copies of such Project Documents are to be delivered by CONSULTANT.
CONSULTANT shall be solely responsible for all costs associated with delivering to OWNER
the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project
Documents for its files and internal use.
6.2. Notwithstanding anything in this Agreement to the contrary and without requiring OWNER
to pay any additional compensation, CONSULTANT hereby grants to OWNER a nonexclusive,
irrevocable license in all of the Project Documents for OWNER'S use on this Project.
CONSULTANT warrants to OWNER that it has full right and authority to grant this license to
OWNER. Further, CONSULTANT consents to OWNER'S use of the Project Documents to
complete the Project following CONSULTANT'S termination for any reason or to perform
additions to or remodeling, replacement or renovations of the Project. CONSULTANT also
acknowledges OWNER may be making Project Documents available for review and information
to various third parties and hereby consents to such use by OWNER.
ARTICLE SEVEN
MAINTENANCE OF RECORDS
7.1. CONSULTANT will keep adequate records and supporting documentation which concern
or reflect its services hereunder. The records and documentation will be retained by
1--PRC-0273811 1 1 0668.'1] 10 (r l
Packet Page -853-
10/14/2014 16.A.20.
CONSULTANT for a minimum of five (5) years from (a) the date of termination of this
Agreement or (b) the date the Project is completed, whichever is later, or such later date as may
be required by law. OWNER, or any duly authorized agents or representatives of OWNER,
shall, free of charge, have the right to audit, inspect and copy all such records and
documentation as often as they deem necessary during the period of this Agreement and during
the five (5) year period noted above, or such later date as may be required by law; provided,
however, such activity shall be conducted only during normal business hours.
ARTICLE EIGHT
INDEMNIFICATION
8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and
hold harmless OWNER, its officers and employees from any and all liabilities, damages, losses
and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the
extent caused by the negligence, recklessness, or intentionally wrongful conduct of
CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this
Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce
any other rights or remedies which otherwise may be available to an indemnified party or person
described in this paragraph.
ARTICLE NINE
INSURANCE
9.1. CONSULTANT shall obtain and carry, at all times during its performance under the
Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to
this Agreement.
9.2. All insurance shall be from responsible companies duly authorized to do business in the
State of Florida.
9.3. All insurance policies required by this Agreement shall include the following provisions
and conditions by endorsement to the policies:
[14-PRC-02738/1110668/I] 11
Packet Page -854-
10/14/2014 16.A.20.
9.3.1. All insurance policies, other than the Business Automobile policy, Professional
Liability policy, and the Workers Compensation policy, provided by CONSULTANT to
meet the requirements of this Agreement shall name Collier County Government, Collier
County, Florida, as an additional insured as to the operations of CONSULTANT under
this Agreement and shall contain a severability of interests provisions.
9.3.2. Companies issuing the insurance policy or policies shall have no recourse against
OWNER for payment of premiums or assessments for any deductibles which all are at
the sole responsibility and risk of CONSULTANT.
9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self-
insurance program carried by OWNER applicable to this Project, and the "Other
Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any
insurance or self-insurance program carried by OWNER applicable to this Project.
9.3.4. The Certificates of Insurance must read: For any and all work performed on
behalf of Collier County, or reference this contract number.
9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall
be construed in accordance with the laws of the State of Florida.
9.4. CONSULTANT, its subconsultants and OWNER shall waive all rights against each other
for damages covered by insurance to the extent insurance proceeds are paid and received by
OWNER, except such rights as they may have to the proceeds of such insurance held by any of
them.
9.5. All insurance companies from whom CONSULTANT obtains the insurance policies
required hereunder must meet the following minimum requirements:
9.5.1. The insurance company must be duly licensed and authorized by the Department
of insurance of the State of Florida to transact the appropriate insurance business in the
State of Florida.
9.5.2. The insurance company must have a current A. M. Best financial rating of "Class
VI" or higher.
[14-PRC-02738/11 10668/1] 12
Packet Page -855-
10/14/2014 16.A.20.
ARTICLE TEN
SERVICES BY CONSULTANT'S OWN STAFF
10.1. The services to be performed hereunder shall be performed by CONSULTANT'S own
staff, unless otherwise authorized in writing by the OWNER. The employment of, contract with,
or use of the services of any other person or firm by CONSULTANT, as independent consultant
or otherwise, shall be subject to the prior written approval of the OWNER. No provision of this
Agreement shall, however, be construed as constituting an agreement between the OWNER
and any such other person or firm. Nor shall anything in this Agreement be deemed to give any
such party or any third party any claim or right of action against the OWNER beyond such as
may then otherwise exist without regard to this Agreement.
10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign
to the Project to perform the Services required hereunder. Such personnel shall be committed
to this Project in accordance with the percentages noted in Schedule F. CONSULTANT also
has identified each subconsultant and subcontractor it intends to utilize on the Project in
Schedule F. All personnel, subconsultants and subcontractors identified in Schedule F shall not
be removed or replaced without OWNER'S prior written consent.
10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or
subcontractors. By appropriate written agreement, the CONSULTANT shall require each
subconsultant or subcontractor, to the extent of the Services to be performed by the
subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this
Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities
which the CONSULTANT, by this Agreement, assumes toward the OWNER. Each
subconsultant or subcontract agreement shall preserve and protect the rights of the OWNER
under this Agreement with respect to the Services to be performed by the subconsultant or
subcontractor so that the subconsutting or subcontracting thereof will not prejudice such rights.
114-PRC-02738111 10668/11 13 0
Packet Page -856- cc '
10/14/2014 16.A.20.
Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to
enter into similar agreements with its sub-subconsultants or sub-subcontractors.
10.4. CONSULTANT acknowledges and agrees that OWNER is a third party beneficiary of
each contract entered into between CONSULTANT and each subconsultant or subcontractor,
however nothing in this Agreement shall be construed to create any contractual relationship
between OWNER and any subconsultant or subcontractor. Further, all such contracts shall
provide that, at Owner's discretion, they are assignable to OWNER upon any termination of this
Agreement.
ARTICLE ELEVEN
WAIVER OF CLAIMS
11.1. CONSULTANT'S acceptance of final payment shall constitute a full waiver of any and all
claims, except for insurance company subrogation claims, by it against OWNER arising out of
this Agreement or otherwise related to the Project, and except those previously made in writing
in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at
the time of the final payment. Neither the acceptance of CONSULTANT'S services nor payment
by OWNER shall be deemed to be a waiver of any of OWNER'S rights against CONSULTANT.
ARTICLE TWELVE
TERMINATION OR SUSPENSION
12.1. CONSULTANT shall be considered in material default of this Agreement and such default
will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further
set forth in this section, for any of the following reasons: (a) CONSULTANT'S failure to begin
services under the Agreement within the times specified under the Notice(s) to Proceed, or (b)
CONSULTANT'S failure to properly and timely perform the services to be provided hereunder or
as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the
benefit of creditors by CONSULTANT or by any of CONSULTANT'S principals, officers or
directors, or (d) CONSULTANT'S failure to obey any laws, ordinances, regulations or other
[14-PRC-02 738/i 110668/1] 14
Packet Page -857-
10/14/2014 16.A.20.
codes of conduct, or (e) CONSULTANT'S failure to perform or abide by the terms and
conditions of this Agreement, or (f) for any other just cause. The OWNER may so terminate this
Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written
notice of the material default.
12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it
is determined for any reason that CONSULTANT was not in default, or that its default was
excusable, or that OWNER otherwise was not entitled to the remedy against CONSULTANT
provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1
shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and
CONSULTANT's remedies against OWNER shall be the same as and be limited to those
afforded CONSULTANT under paragraph 12.3, below.
12.3. OWNER shall have the right to terminate this Agreement, in whole or in part, without
cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such
termination for convenience, CONSULTANT'S recovery against OWNER shall be limited to that
portion of the fee earned through the date of termination, together with any retainage withheld
and any costs reasonably incurred by CONSULTANT that are directly attributable to the
termination, but CONSULTANT shall not be entitled to any other or further recovery against
OWNER, including, but not limited to, anticipated fees or profits on work not required to be
performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably
possible.
12.4. Upon termination and as directed by Owner, the CONSULTANT shall deliver to the
OWNER all original papers, records, documents, drawings, models, and other material set forth
and described in this Agreement, including those described in Section 6, that are in
CONSULTANT'S possession or under its control.
[14-PRC-0273 8/1 I 10668/1] 15
Packet Page -858-
10/14/2014 16.A.20.
12.5. The OWNER shall have the power to suspend all or any portions of the services to be
provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior
written notice of such suspension. If all or any portion of the services to be rendered hereunder
are so suspended, the CONSULTANT'S sole and exclusive remedy shall be to seek an
extension of time to its schedule in accordance with the procedures set forth in Article Four
herein.
12.6 In the event (i) OWNER fails to make any undisputed payment to CONSULTANT within
forty-five (45) days after such payment is due or such other time as required by Florida's Prompt
Payment Act or (ii) OWNER otherwise persistently fails to fulfill some material obligation owed
by OWNER to CONSULTANT under this Agreement, and (ii) OWNER has failed to cure such
default within fourteen (14) days of receiving written notice of same from CONSULTANT, then
CONSULTANT may stop its performance under this Agreement until such default is cured, after
giving OWNER a second fourteen (14) days written notice of CONSULTANT's intention to stop
performance under the Agreement. If the Services are so stopped for a period of one hundred
and twenty (120) consecutive days through no act or fault of the CONSULTANT or its
subconsultant or subcontractor or their agents or employees or any other persons performing
portions of the Services under contract with the CONSULTANT, the CONSULTANT may
terminate this Agreement by giving written notice to OWNER of CONSULTANT'S intent to
terminate this Agreement. If OWNER does not cure its default within fourteen (14) days after
receipt of CONSULTANT'S written notice, CONSULTANT may, upon fourteen (14) additional
days' written notice to the OWNER, terminate the Agreement and recover from the Owner
payment for Services performed through the termination date, but in no event shall
CONSULTANT be entitled to payment for Services not performed or any other damages from
Owner.
X14-PRC-02738/1 1 10668'1] 16 �L)
Packet Page -859-
10/14/2014 16.A.20.
ARTICLE THIRTEEN
TRUTH IN NEGOTIATION REPRESENTATIONS
13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company
or person, other than a bona fide employee working solely for CONSULTANT, to solicit or
secure this Agreement and that CONSULTANT has not paid or agreed to pay any person,
company, corporation, individual or firm, other than a bona fide employee working solely for
CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent
upon or resulting from the award or making of this Agreement.
13.2. In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the
CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto
and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs
supporting the compensation for CONSULTANT'S services to be provided under this
Agreement are accurate, complete and current at the time of the Agreement. The
CONSULTANT agrees that the original Agreement price and any additions thereto shall be
adjusted to exclude any significant sums by which the OWNER determines the Agreement price
was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit
costs. All such adjustments shall be made within one (1) year following the end of this
Agreement.
ARTICLE FOURTEEN
CONFLICT OF INTEREST
14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest,
either direct or indirect, which would conflict in any manner with the performance of services
required hereunder. CONSULTANT further represents that no persons having any such interest
shall be employed to perform those services.
[14-PRC-02 7 3 811 1 1 0668/1] 17
Packet Page -860-
10/14/2014 16.A.20.
ARTICLE FIFTEEN
MODIFICATION
15.1. No modification or change in this Agreement shall be valid or binding upon either party
unless in writing and executed by the party or parties intended to be bound by it.
ARTICLE SIXTEEN
NOTICES AND ADDRESS OF RECORD
16.1. All notices required or made pursuant to this Agreement to be given by the
CONSULTANT to the OWNER shall be in writing and shall be delivered by hand, by fax, or by
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following OWNER'S address of record:
Board of County Commissioners
Collier County Florida
Purchasing Department
3327 Tamiami Trail East
Naples, FL 34112
Attention: Joanne Markiewicz, Director, Procurement Services
Telephone: 239-252-8407
Fax: 239-252-6480
16.2. All notices required or made pursuant to this Agreement to be given by the OWNER to
the CONSULTANT shall be made in writing and shall be delivered by hand, by fax or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following CONSULTANT'S address of record:
Humiston & Moore Engineers, P.A.
5679 Strand Court
Naples, FL 34110
Telephone: 239-594-2021
FAX: 239-594-2025
Attn: Brett D. Moore, PE
16.3. Either party may change its address of record by written notice to the other party given in
accordance with requirements of this Article.
[14-PRC-02738/1 1 1 0668/1] 18
Packet Page -861-
10/14/2014 16.A20.
ARTICLE SEVENTEEN
MISCELLANEOUS
17.1. CONSULTANT, in representing OWNER, shall promote the best interests of OWNER
and assume towards OWNER a duty of the highest trust, confidence, and fair dealing.
17.2. No modification, waiver, suspension or termination of the Agreement or of any terms
thereof shall impair the rights or liabilities of either party.
17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by
CONSULTANT without the prior written consent of OWNER.
17.4. Waivers by either party of a breach of any provision of this Agreement shall not be
deemed to be a waiver of any other breach and shall not be construed to be a modification of
the terms of this Agreement.
17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this
Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or
change the provisions in such Articles, Schedules, Parts and Attachments.
17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes
the entire agreement between the parties hereto and shall supersede, replace and nullify any
and all prior agreements or understandings, written or oral, relating to the matter set forth
herein, and any such prior agreements or understanding shall have no force or effect whatever
on this Agreement.
17.7. Unless otherwise expressly noted herein, all representations and covenants of the parties
shall survive the expiration or termination of this Agreement.
[14-PRC-0273 8/1 1 1 066811] 19 ( <* 1
Packet Page -862-
10/14/2014 16.A.20.
17.8. This Agreement may be simultaneously executed in several counterparts, each of which
shall be an original and all of which shall constitute but one and the same instrument.
17.9. The terms and conditions of the following Schedules attached hereto are by this
reference incorporated herein:
Schedule A SCOPE OF SERVICES
Schedule B BASIS OF COMPENSATION
Schedule C PROJECT MILESTONE SCHEDULE
Schedule D INSURANCE COVERAGE
Schedule E TRUTH IN NEGOTIATION CERTIFICATE
Schedule F KEY PERSONNEL, SUBCONSULTANTS AND
SUBCONTRACTORS
RFP # 14-6257 Engineering Services for Doctors Pass Jetty Terms and
Conditions
Consultant's Proposal
ARTICLE EIGHTEEN
APPLICABLE LAW
18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of
Florida, and by such laws, rules and regulations of the United States as made applicable to
services funded by the United States government. Any suit or action brought by either party to
this Agreement against the other party relating to or arising out of this Agreement must be
brought in the appropriate federal or state courts in Collier County, Florida, which courts have
sole and exclusive jurisdiction on all such matters.
ARTICLE NINETEEN
SECURING AGREEMENT/PUBLIC ENTITY CRIMES
19.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company
or person, other than a bona fide employee working solely for CONSULTANT, to solicit or
[14-PRC-02 7 3 8/1 1 1 0668/1] 20 J
Packet Page -863-
10/14/2014 16.A.20.
secure this Agreement and that CONSULTANT has not paid or agreed to pay any person,
company, corporation, individual or firm, other than a bona fide employee working solely for
CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent
upon or resulting from the award or making of this Agreement. At the time this Agreement is
executed, CONSULTANT shall sign and deliver to OWNER the Truth-In-Negotiation Certificate
identified in Article 13 and attached hereto and made a part hereof as Schedule E.
CONSULTANT'S compensation shall be adjusted to exclude any sums by which OWNER
determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage
rates and other factual unit costs.
19.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been
informed by OWNER of and is in compliance with the terms of Section 287.133(2)(a) of the
Florida Statutes which read as follows:
"A person or affiliate who has been placed on the convicted vendor list
following a conviction for a public entity crime may not submit a bid,
proposal, or reply on a contract to provide any goods or services to a public
entity; may not submit a bid, proposal, or reply on a contract with a public
entity for the construction or repair of a public building or public work; may
not submit bids, proposals, or replies on leases of real property to a public
entity, may not be awarded or perform work as a contractor, supplier,
subcontractor, or consultant under a contract with any public entity; and
may not transact business with any public entity in excess of the threshold
amount provided in s. 287.017 for CATEGORY TWO for a period of 36
months following the date of being placed on the convicted vendor list."
ARTICLE TWENTY
DISPUTE RESOLUTION
20.1 Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any such
disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT
with full decision-making authority and by OWNER'S staff person who would make the
presentation of any settlement reached during negotiations to OWNER for approval. Failing
resolution, and prior to the commencement of depositions in any litigation between the parties
arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation
[14-PRC-02738/1110668/1] 21 (
Packet Page -864-
10/14/2014 16.A.20.
before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation
shall be attended by representatives of CONSULTANT with full decision-making authority and
by OWNER'S staff person who would make the presentation of any settlement reached at
mediation to OWNER'S board for approval. Should either party fail to submit to mediation as
required hereunder, the other party may obtain a court order requiring mediation under section
44.102, Fla. Stat.
20.2 Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
III
ARTICLE 21
IMMIGRATION LAW COMPLIANCE
21.1 By executing and entering into this agreement, the CONSULTANT is formally
acknowledging without exception or stipulation that it is fully responsible for complying with the
provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et
seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT
to comply with the laws referenced herein shall constitute a breach of this agreement and the
County shall have the discretion to unilaterally terminate this agreement immediately.
**********
(The remainder of this page is intentionally left blank.)
114-PRC-02738/1 1 1 0668/1) 22
Packet Page -865-
1
10/14/2014 16.A.20.
IN WITNESS WHEREOF, the parties hereto have executed this Professional Services
Agreement for Engineering Services for Doctors Pass Jetty on the day and year first written
above.
ATTEST: BOARD OF COUNTY COMMISSIONERS FOR
COLLIER COUNTY, FLORIDA,
Dwight E. Brock, Clerk
By:
Date: By:
Tom Henning, Chairman
roved as to Form and Legality:
sistant County Attorney
Name
Humiston & Moore Engineers, P.A.
By:
Witness
Name and Title Name and Title
Witness
Name and Title
V
23
Packet Page -866-