Agenda 06/27/2017 Item #11E06/27/2017
EXECUTIVE SUMMARY
Recommendation to award Invitation to Bid No. 17-7125 to Marine Contracting Group, Inc., for
the Cocohatchee River Park Marina Renovations, in the amount of $1,394,000, plus $5,000 for
County permitting fees for a total of $1,399,000.
OBJECTIVE: To replace the deteriorated dock structures at the Cocohatchee River Marina Park.
CONSIDERATIONS: The existing docks are approximately 32 years old, are reaching the end of their
useful lives, and several emergency repairs have been necessary. A structural inspection of the existing
conditions confirmed the docks require full replacement. The scope of the project includes replacing the
dock structure within the existing footprint, replacing the concrete boat ramp, upgrading the electrical
service, and replacing the water utility.
On March 30, 2017, the Procurement Services Division released notices of Invitation to Bid No. 17-7125,
“Cocohatchee River Park Marina Renovations,” to 2,550 vendors. One-hundred forty-seven bid packages
were downloaded. Three bids were received May 1, 2017, as shown below and on the attached Bid
Tabulation.
The lowest bidder was 10% over the engineers estimate and did not/could not provide a bid bond or
deposit at the time of the bid submittal and was therefore deemed not responsive and disqualified. The
next lowest bid was over 40% of the engineers estimate. The two qualified bidders were not as familiar
with the site conditions as the disqualified bidder and likely bid higher to account for that contingency.
Marina and dock construction requires a specialized contractor that is in high demand during the summer
season. The bids received reflect current market conditions as stated in the attached engineer's
recommendation.
Per Purchasing Ordinance 12.2.b, the contract was further negotiated with low bidder Marine Contracting
Group, Inc., from a lump sum base bid of $1,494,000 to $1,394,000. The lowest qualified base bid,
following further negotiation to arrive at a figure within the project’s budgeted amount, is approximately
26 percent above the consultant engineer’s cost estimate of $1,107,590. Staff reviewed the lump sum
base bid and pricing for one Add Alternate. Facilities staff elected to award the base bid only. Staff
recommends awarding the contract to Marine Contracting Group, Inc., the lowest, responsible and
responsive bidder.
Contractor Base Bid Add Alternate
(Replace Boat Ramp)
TOTAL (Base Bid +
Add Alternate)
1 Marine Contracting Group, Inc. $1,394,000 $175,000 $1,569,000
2 Shoreline Foundation, Inc. $1,595,603 $231,000 $1,823,603
3 Greg Orick II Marine
Construction, Inc. (Disqualified)
$1,128,730 $115,335 $1,244,065
Due to budgeting restraints, the Add Alternate of replacing the concrete boat ramp will be addressed later.
The structural inspection reported that the boat ramp was not a critical repair item and that patching
repairs could extend its useful life five to eight years. Necessary boat ramp repairs will be addressed with
this project through the project’s budgeted allowance.
The replacement design is safer and eliminates the step down to each finger pier. It also provides
Americans with Disabilities Act accessibility to two dock sections. In addition, to extend the average life
expectancy, the dock piles will be wrapped to protect them from degradation in the harsh marine
11.E
Packet Pg. 498
06/27/2017
environment.
FISCAL IMPACT: The bid award is $1,394,000. Also anticipated is $5,000 for permitting and ancillary
site work for a total construction phase budget of $1,399,000. Funding is available and appropriated for
this project (Project No. 80282, Cocohatchee Park Bulkhead Repairs) within the Parks Boating
Improvement Fund (303). The source of funding is boater vessel registration fees.
GROWTH MANAGEMENT IMPACT: None.
LEGAL CONSIDERATIONS: This item is approved as to form and legality, and requires majority
vote for Board approval. -SRT
RECOMMENDATION: To award Bid No. 17-7125 to Marine Contracting Group, Inc., for the
Cocohatchee River Marina Renovations, Project No. 80282, in the amount of $1,394,000, plus $5,000 for
County permitting fees for a total of $1,399,000; and, authorize the Chair to execute the attached contract.
Prepared by: Felicia Kirby, Associate Project Manager, Facilities Management Division
ATTACHMENT(S)
1. 17-7125 Bid Tabulation (PDF)
2. [Linked] 17-7125 Contract (PDF)
3. Opinion of Probable Cost (PDF)
4. NORA and Engineers Recommendation (PDF)
11.E
Packet Pg. 499
06/27/2017
COLLIER COUNTY
Board of County Commissioners
Item Number: 11.E
Doc ID: 3129
Item Summary: Recommendation to award Invitation to Bid No. 17-7125 to Marine Contracting
Group, Inc., for the Cocohatchee River Park Marina Renovations, in the amount of $1,394,000, plus
$5,000 for county permitting fees for a total of $1,399,000. (Felicia Kirby, Project Manager, Facilities
Management Division)
Meeting Date: 06/27/2017
Prepared by:
Title: – Facilities Management
Name: Felicia Kirby
05/25/2017 11:38 AM
Submitted by:
Title: Division Director - Facilities Mgmt – Facilities Management
Name: Dennis Linguidi
05/25/2017 11:38 AM
Approved By:
Review:
Public Utilities Department Margie Hapke Additional Reviewer Completed 05/25/2017 3:56 PM
Facilities Management Dennis Linguidi Additional Reviewer Completed 05/25/2017 5:15 PM
Procurement Services Barbara Lance Level 1 Purchasing Gatekeeper Completed 05/30/2017 12:29 PM
Procurement Services Ted Coyman Additional Reviewer Completed 05/31/2017 5:25 PM
Parks & Recreation Barry Williams Additional Reviewer Completed 06/01/2017 4:28 PM
Procurement Services Sandra Herrera Additional Reviewer Completed 06/02/2017 10:50 AM
Public Utilities Operations Support Joseph Bellone Additional Reviewer Completed 06/05/2017 1:27 PM
Public Utilities Department Heather Bustos Additional Reviewer Completed 06/05/2017 4:19 PM
Public Services Department Steve Carnell Additional Reviewer Completed 06/12/2017 1:34 PM
County Attorney's Office Colleen Greene Additional Reviewer Completed 06/14/2017 4:32 PM
County Attorney's Office Scott Teach Level 2 Attorney Review Completed 06/15/2017 9:44 AM
Facilities Management Margaret Bishop Additional Reviewer Completed 06/06/2017 10:23 AM
Solid and Hazardous Waste Dan Rodriguez Additional Reviewer Completed 06/06/2017 3:43 PM
Office of Management and Budget Valerie Fleming Level 3 OMB Gatekeeper Review Completed 06/15/2017 10:51 AM
County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 06/16/2017 3:55 PM
Budget and Management Office Ed Finn Additional Reviewer Completed 06/16/2017 5:06 PM
11.E
Packet Pg. 500
06/27/2017
Office of Management and Budget Susan Usher Additional Reviewer Completed 06/16/2017 5:19 PM
County Manager's Office Leo E. Ochs Level 4 County Manager Review Completed 06/20/2017 11:34 AM
Board of County Commissioners MaryJo Brock Meeting Pending 06/27/2017 9:00 AM
11.E
Packet Pg. 501
Jim Flanagan, Procurement Strategist Notifications Sent: 2555
Felicia Kirby, Project Manager Downloaded: 147
Submittals: 3
May 1, 2017 17-7125 Bid Tabulation Contractor:
Project:Cocohatchee River Park Marina Renovations REVISED
Description:Marina Repair and Replacment Costs
ITEM NO.ITEM DESCRIPTION QUANTITY UNIT UNIT COST COST PER ITEM UNIT COST COST PER ITEM UNIT COST COST PER ITEM UNIT COST COST PER ITEM
1.1-1.2 MOBILIZATION & DEMOBILIZATION 1 LS $65,000.00 $65,000 $65,000.00 $65,000 $62,100.00 $62,100 $14,650.00 $14,650
2.1-2.3 DEMOLITION & DISPOSAL 1 LS $80,000.00 $80,000 $80,000.00 $80,000 $206,000.00 $206,000 $59,550.00 $59,550
3.1-3.3, 3.6-3.7 FIXED DOCK (EXCLUDING PILES)1 LS $336,200.00 $336,200 $386,200.00 $386,200 $300,000.00 $300,000 $417,845.00 $417,845
3.4-3.5 DOCK PILES 1 LS $271,000.00 $271,000 $321,000.00 $321,000 $339,926.00 $339,926 $178,155.00 $178,155
4.2 FIRE EXTINGUISHERS 1 LS $30,000.00 $30,000 $30,000.00 $30,000 $17,000.00 $17,000 $14,705.00 $14,705
4.4 WATER SERVICE 1 LS $56,000.00 $56,000 $56,000.00 $56,000 $73,197.00 $73,197 $8,540.00 $8,540
4.5 ELECTRICAL SERVICE 1 LS $170,000.00 $170,000 $170,000.00 $170,000 $199,628.00 $199,628 $109,075.00 $109,075
4.7 SECURITY GATES 1 LS $5,000.00 $5,000 $5,000.00 $5,000 $13,000.00 $13,000 $4,860.00 $4,860
4.8 POWER PEDESTALS 1 LS $49,025.00 $49,025 $49,025.00 $49,025 $60,369.00 $60,369 $52,525.00 $52,525
5.1-5.4 MOORING PILES 1 LS $17,000.00 $17,000 $17,000.00 $17,000 $26,930.00 $26,930 $11,325.00 $11,325
6.1 SEAWALL CAP REPLACEMENT (ZONE 3 AND 4)1 LS $58,275.00 $58,275 $58,275.00 $58,275 $78,800.00 $78,800 $78,445.00 $78,445
6.1 TIE-BACK/DEADMAN REPLACEMENT (ZONE 3)1 LS $5,000.00 $5,000 $5,000.00 $5,000 $12,820.00 $12,820 $13,300.00 $13,300
6.1 EXCAVATION OF TIE-BACK ZONE 5 1 LS $9,000.00 $9,000 $9,000.00 $9,000 $15,673.00 $15,673 $10,990.00 $10,990
7.1 SIDEWALKS 1 LS $15,000.00 $15,000 $15,000.00 $15,000 $18,380.00 $18,380 $5,745.00 $5,745
12.0 PROJECT SIGN 1 LS $2,500.00 $2,500 $2,500.00 $2,500 $13,682.00 $13,682 $1,775.00 $1,775
FDOT 401-70-1 SPALL REPAIR 1 LS $75,000.00 $75,000 $75,000.00 $75,000 $29,600.00 $29,600 $26,250.00 $26,250
FDOT 411-2 CRACK REPAIR 1 LS $50,000.00 $50,000 $50,000.00 $50,000 $28,498.00 $28,498 $20,995.00 $20,995
BASE BID TOTAL TOTAL $1,294,000 TOTAL $1,394,000 TOTAL $1,495,603 TOTAL $1,028,730
-OWNERS ALLOWANCE $100,000 $100,000 $100,000 $100,000
TOTAL BID $1,394,000 $1,494,000 $1,595,603 $1,128,730
ADD ALTERNATE
ITEM NO.ITEM DESCRIPTION QUANTITY UNIT UNIT COST COST PER ITEM UNIT COST COST PER ITEM UNIT COST COST PER ITEM
8.1-8.7 BOAT RAMP REPLACEMENT 1 LS $175,000.00 $175,000 $175,000.00 $175,000 $231,000.00 $231,000 $115,335.00 $115,335
TOTAL INCLUDING ALATERNATE $1,569,000 $1,669,000 $1,826,603 $1,244,065
UNIT PRICES FOR UNFORESEEN ITEMS (NOT PART OF BASE BID OR ADD ALTERNATE)
ITEM NO.ITEM DESCRIPTION QUANTITY UNIT UNIT COST COST PER ITEM UNIT COST COST PER ITEM UNIT COST COST PER ITEM UNIT COST COST PER ITEM
1.0 VESSEL RELOCATION* (Based on 1-8 EA)8 LS $1,500.00 $12,000 $1,500.00 $12,000 $4,379.00 $35,032 $1,075.00 $8,600
2.0 ADDITIONAL CLEATS** (Based on 2-15 EA)15 LS $125.00 $1,875 $125.00 $1,875 $68.00 $1,020 $25.00 $375
6.1 TIE-BACK REPAIR - (Based on 2-10 EA)10 ea $2,000.00 $20,000 $2,000.00 $20,000 $498.00 $4,980 $725.00 $7,250
FDOT 401-70-1 ADDITIONAL SPALL REPAIR - (Based on 10-50 CF)50 cf $300.00 $15,000 $300.00 $15,000 $65.00 $3,250 $300.00 $15,000
FDOT 411-2 ADDITIONAL CRACK REPAIR - (Based on 10-50 LF )50 lf $150.00 $7,500 $150.00 $7,500 $99.00 $4,950 $162.00 $8,100
PROJECTED UNIT PROICE ITEMS TOTAL SUM $56,375 $56,375 $49,232 $39,325
Completed Bid Form (solicitation page 12)Y Y Y
Completed Bid Schedule (as REVISED - 17-7125 Bid Schedule - ADD#2rev)Y Y Y
Completed Bid Forms:
Material Manufacturers (solicitation page 14)y Y Y
List of Major Subcontractors (solicitation page 15)Y Y Y
Statement of Experience of Bidder (soliciation page 16 Y Y Y
Trench Safety Act Acknowledgement (solicitation page 17)Y Y Y
E-Verify Immigration Law Affidavit Certification (solicitation page 18)y Y Y
Solicitations Substitute W-9 (solicitation page 19-22)y Y Y
Bid Bond Form (solicitaiton page 23)y Y N
Bidders Checklist (solitication page 24)y Y Y
Insurance and Bonding Requirements (solicitation pages 41 and 42)y Y Y
Project Schedule/Zone Schedule (indicated on 17-7125 Bid Schedule)Y Y Y
Unit Prices (indicated on 17-7125 Bid Schedule)y Y Y
Acknowledgement - Receipt of Addendum #1 y Y N
Acknowledgement - Receipt of Addendum #2 y Y N
Acknowledgement - Receipt of Addendum #3 y Y N
Strategist: Confirm validity w/FL Divisions of Corporations on-line Y Y Y
Strategist: Confirm Insurance and Bonding Requirements N
Strategist: CONFIRM ALL BID DOCUMENTS COMPLETED AND SIGNED:Y Y N
The contractor shall submit a proposed schedule that provides the estimated number of weeks to replace each zone
and a total time schedule to complete the entire project.
Opened By: Jim Flanagan, Procurement Strategist
Witnessed By: Swainson Hall, Procurement Manager - Acquisitions
Marine Contracting Group Shoreline Foundation Inc Greg Orek II Marine Construction
BID TABULATION
Marine Contracting Group
11.E.1
Packet Pg. 502 Attachment: 17-7125 Bid Tabulation (3129 : Cocohatchee Marina Renovations)
7-Nov-16
Client:Collier County
Project:Cocohatchee River Park Marina
County:Collier
Description:Marina Repair and Replacment Costs
ITEM NO.ITEM DESCRIPTION QUANTITY UNIT UNIT COST COST PER ITEM
1.1-1.2 MOBILIZATION & DEMOBILIZATION 1 LS $50,000.00 $50,000
2.1-2.3 DEMOLITION & DISPOSAL 8488 SF $10.00 $84,875
3.1-3.3, 3.6-3.7 FIXED DOCK (EXCLUDING PILES)7998 SF $30.00 $239,925
3.4-3.5 DOCK PILES 321 EA $500.00 $160,500
4.2 FIRE EXTINGUISHERS 17 EA $100.00 $1,700
4.4 WATER SERVICE 1 LS $100,000.00 $100,000
4.5 ELECTRICAL SERVICE 1 LS $150,000.00 $150,000
4.7 SECURITY GATES 15 LF $25.00 $375
4.8 POWER PEDESTALS 20 EA $1,500.00 $30,000
5.1-5.4 MOORING PILES 17 EA $500.00 $8,500
6.1 SEAWALL CAP REPLACEMENT (ZONE 3 AND 4)333 LF $175.00 $58,275
6.1 TIE-BACK/DEADMAN REPLACEMENT (ZONE 3)1 EA $5,000.00 $5,000
6.1 EXCAVATION OF TIE-BACK ZONE 5 1 LS $5,000.00 $5,000
7.1 SIDEWALKS 98 LF $30.00 $2,940
8.1-8.7 BOAT RAMP REPLACEMENT 1 LS $70,000.00 $70,000
12.0 PROJECT SIGN 1 EA $500.00 $500
FDOT 401-70-1 SPALL REPAIR 1 LS $35,000.00 $35,000
FDOT 411-2 CRACK REPAIR 1 LS $5,000.00 $5,000
TOTAL $1,007,590
ITEM NO.ITEM DESCRIPTION QUANTITY UNIT UNIT COST COST PER ITEM
1.0 VESSEL RELOCATION*8 EA $1,250.00 $10,000
2.0 ADDITIONAL CLEATS**80 EA $62.50 $5,000
4.3 INSTALL SALVAGED CLEATS 80 EA $25.00 $2,000
4.6 TEMPORARY MOORING SUPPLIES 1 LS $7,500.00 $7,500
6.1 TIE-BACK REPAIR 10 EA $2,500.00 $25,000
FDOT 401-70-1 ADDITIONAL SPALL REPAIR 50 CF $350.00 $17,500
FDOT 411-2 ADDITIONAL CRACK REPAIR 24 LF $70.00 $1,680
-OVERALL CONTINGENECY ALLOWANCE 1 LS $50,000.00 $50,000
TOTAL $1,126,270
The contractor shall submit a proposed schedule that provides the estimated number of weeks to replace each zone
and a total time schedule to complete the entire project.
ENGINEER OPINION OF PROBABLE COST
ALLOWANCES
*$10,000 for moving renter’s boats as requested by the county.
Provide a unit price per vessel for Contractor to move a renter’s vessel from its slip to a temporary mooring location as
determined by the County, safely secure said vessel until the permanent slip has been completely renovated, and then
to replace said vessel in its permanent slip and safely secure it. The temporary mooring location will involve double
breasting vessels as shown on Temporary Mooring Attachment and the use of contractor supplied mooring fenders and
floating “Camels”.
$___________per vessel.
**$5,000 to furnish and install additional (to those shown on the drawings) 12” HDG Cleats, Model # 040112 by Sea-
Dog Marine or approved equal.
Provide a unit price per cleat to furnish and install additional (not shown on the drawings) 12” HDG Cleats, Model #
040112 by Sea-Dog Marine, or approved equal.
$___________per cleat.
11.E.3
Packet Pg. 503 Attachment: Opinion of Probable Cost (3129 : Cocohatchee Marina Renovations)
11.E.4
Packet Pg. 504 Attachment: NORA and Engineers Recommendation (3129 : Cocohatchee Marina Renovations)
We design bridges to fit your site and budget.
Bridging Solutions, LLC
15863 Secoya Reserve Circle
Naples, FL 34110
Tel. (239) 216-1370
ralph@bridging-solutions.com
www.bridging-solutions.com
June 20, 2017
Margaret A. Bishop, P.E.
Senior Project Manager
Facilities Management Department
Collier County Government
3299 Tamiami Trail East
Naples, FL 34112
RE: Cocohatchee River Park Marina
13535 Vanderbilt Drive, Naples, FL
Bid Review
Dear Ms. Bishop:
Bridging Solutions, LLC believes the bid of the apparent low bidder Marine Contracting Group, Inc. (MCG) on the
subject project reflects the current market conditions in Collier County. The following list provides a summary of
our evaluation of the unit bid prices submitted by MCG which provides some insight into why we believe their bid
is approximately 43% higher than our engineers estimate.
1. Our estimated unit costs for most of the bid items were based on prices bid on past similar projects in the
private sector. In hind sight, it appears that we should have factored the private bid prices higher to account
for the dynamics of a contractor dealing with the County compared to a private marina owner.
2. The low bidder, Greg Orek II Marine Construction, was only 10% over our estimate and the next bidder
(MCG) was over by 40%. Unfortunately they were not able to secure bonding.
3. MCG's bid price for the concrete repair items were very high compared to our estimate and the other 2
bidders. This accounts for almost 8% of the difference in just 2 work items.
4. MCG’s bid for the piles is 2 times our estimate and the bid by the low bidder. They were not as familiar
with the site conditions as the low bidder so they likely bid higher to account for this contingency. This one
item accounts for almost 15% of the difference.
Please contact me at 239-216-1370 if you have any questions or comments.
Respectfully,
BRIDGING SOLUTIONS, LLC
Ralph Verrastro, PE
Principal
11.E.4
Packet Pg. 505 Attachment: NORA and Engineers Recommendation (3129 : Cocohatchee Marina Renovations)
C
q Aev Couvity
Administrati've Services Depaement,
Cocohatchee River Park Marina Renovations
COLLIER COUNTY BID NO. 17-7125
COLLIER COUNTY, FLORIDA
W. James Flanagan 111, Procurement Strategist
Email: JimFlanagan@colliergov.net
Telephone: (239) 252 - 8946
Design Professional:
a
F�!('Ajfeme': n , "�,7 1 mr-mi: I I E �,s • Nanitt.,. HOrA.-, 154 112-490 1 - 23� -2.EMV - ,w,'
1
Construction Services Agreement: Revised 02132017
PUBLICNOTICE ....................................................................................................................... 3
PART B - INSTRUCTIONS TO BIDDERS .................................................................................
5
CONSTRUCTIONBID ..............................................................................................................
12
BIDSCHEDULE .......................................................................................................................
1J
MATERIALMANUFACTURERS ..............................................................................................
14
LIST QFMAJOR SUBCONTRACTORS ..................................................................................
14
STATEMENT OF EXPERIENCE OF BIDDER ..........................................................................
1G
TRENCHSAFETY ACT ............................................................................................................
17
IMMIGRATION LAW AFFIDAVIT CERTIFICATION .................................................................
18
COLLIER COUNTY SOLICITATIONS SUBSTITUTE VV -9 .....................................................
19
BIDBOND ................................................................................................................................
23
BIDDERSCHECK LIST ...........................................................................................................
24
CONSTRUCTIONAGREEMENT ..............................................................................................
26
EXHIBIT A1:PUBLIC PAYMENT BOND ................................................................................
32
EXHIBIT A2: PUBLIC PERFORMANCE BOND ......................................................................
35
EXHIBIT EB:INSURANCE REQUIREMENTS ............................................................................
3B
EXHIBIT C: RELEASE AND AFFIDAVIT FORM ......................................................................
*2
EXHIBIT C>:FORM OF CONTRACT APPLICATION FOR PAYMENT .....................................
43
EXHIBIT E:CHANGE OR0ER---------.-----.-----------------..
44
EXHIBIT F:CERTIFICATE OF SUBSTANTIAL CONYPLET|ON---------------..
45
EXHIBIT G:FINAL PAYMENT CHECKLIST ............................................................................
*/
EXHIBIT H: GENERAL TERMS AND CONDITIONS ................................................................
48
EXHIBIT 1: SUPPLEMENTAL TERMS AND CONDITIONS ......................................................
75
EXHIBIT J:TECHNICAL SPECIFICATIONS ...........................................................................
76
EXHIBITNZPERMITS ..............................................................................................................
//
EXHIBITL: STANDARD DETAILS ..........................................................................................
78
EXHIBIT K8:PLANS AND SPECIFICATIONS ..........................................................................
79
EXHIBIT N: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT ...............
80
o
Construction ServiceAgreement: Revised co1mm17
Administrative SeNlces Department
PUBLIC NOTICE
INVITATION TO BID
CuoohatoheeRiver Park Marina Renovations
COUNTY BID NO. 17-7125
Sealed bids for the construction of Cocohatchee River Park Marina Renovations will be received
electronically until 2:30 P.M. LOCAL T|K8E' on the 1st day Of May, 2017 on the County's on-
line bidding system: . All bids will be publicly opened and read
aloud. Any bids received after the time and date specified will not be accepted and ahoU be
returned unopened tOthe Bidder. The anticipated project budg8tio: $1.120.270.
A non -mandatory pre-bid conference shall be held at the Project Site at C000hatohee River
Pork M3rina, 13531 Vanderbilt [)rive' Nop|8a. FL at 9:00 a.m. LOCAL TIME on the 12th day of
April 2017. at which time all prospective Bidders may have questions answered regarding the
Bidding Documents for this Project.
Bids aho|| be received on line by the Bid Date of May 1, 2017. No bid shall be considered
un|8aa it is made on unaltered Bid forms which are included in the Bidding Documents. One
contract will be awarded for all Work. Bidding Documents may be examined On the Collier
County Procurement 8Sm|maa Division Online Bidding System website: .
Copies of the Bidding Documents may be obtained only from the denoted website. Bidding
Documents obtained from sources other than the Collier County Procurement Services Division
website may not b8accurate 0rcurrent.
Each bid shall be accompanied by a certified or cashiers check or a Bid Bond in an amount not
|eoo than five percent (596) of the total Bid to be retained as liquidated donnagao in the event the
8uomaasfu| Bidder fails to execute the Agreement and file the required bonds and insurance
within ten (10) calendar days after the receipt of the N0UCa of Award. The Successful Bidder
acknowledges and agrees that it shall execute the Agreement in the form attached hereto and
incorporated herein.
The 8uocooafu| Bidder shall be required to furnish the necessary Payment and Performance
Bonda, as prescribed in the General Conditions ofthe Contract Documents. All Bid Bonda,
Payment and Performance Bonds, Insurance Contracts and Certificates ofInsurance shall be
either executed by or countersigned by n |io8noad resident agent of the aun3tv or insurance
company having its place Of business in the State of Florida. Further, the said surety or
insurance company shall be duly licensed and qualified to do business in the State of Florida.
AttorneyS-in-factthat sign Bid Bonds or Payment and Performance Bonds must file with each
bond ocertified and effective dated copy oftheir Power ofAttorney.
In order to perform public work, the GuCCasofu| Bidder shall, as app||o8b|a, hold or obtain such
contractor's and business licenses, certifications and registrations as required by State statutes
and County ordinances.
Before a contract will be 8vv8nded for the Work onntannp|ot9d herein. the Owner ahoU conduct
such investigations as it deems necessary to determine the performance record and ability of
the apparent |ovv Bidder to perform the size and type of work specified in the Bidding
n
Construction Services Agreement: Revised 02132017
Documents. Upon request, the Bidder shall submit such information as deemed necessary by
the Owner toevaluate the Bidder's qualifications.
The Successful Bidder shall be required to finally complete all Work within One Hundred Fifty
(150) calendar days from and after the Commencement Date specified in the Notice to Proceed.
The {}vvnSr peaen/ae the right to reject all Bids or any Bid not conforming to the intent and
purpose of the Bidding Documents, and to postpone the award of the contract for 8 period Of
time which, however, aho|| not extend beyond one hundred twenty (120) days from the bid
opening date vvithouttheconsent 0fthe Successful Bidder.
Dated this 301h day of March 2017
BOARD DFCOUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
BY:
Director, Procurement Services Division
4
Construction Services Agreement: Revised 02132017
1.1 The term "Owner" used herein refers to the Board of County Commissioners, or its duly
authorized representative.
1.2 The term "Project Manager" used herein refers to the Owner's duly authorized
representative and shall mean the Division Administrator or Department Director, as applicable,
acting directly or through duly authorized representatives.
1.3 The term "Design Professional" refers to the licensed professional engineer or architect
who is in privity with the Owner for the purpose of designing and/or monitoring the construction
of the project. At the Owner's discretion, any or all duties of the Design Professional referenced
in the Contract Documents may be assumed at any time by the Project Manager on behalf of
the Owner. Conversely, at the Owner's discretion the Project Manager may formally assign any
of his/her duties specified in the Contract Documents to the Design Professional.
1.4 The term "Bidder" used herein means one who submits a bid directly to the Owner in
response to this solicitation.
1.5 The term "Successful Bidder" means the lowest, qualified, responsible and responsive
Bidder who is awarded the contract by the Board of County Commissioners, on the basis of the
Owner's evaluation.
1.6 The term "Bidding Documents" includes the Legal Advertisement, these Instructions to
Bidders, the Bid Schedule and the Contract Documents as defined in the Agreement.
1.7 The term "Bid" shall mean a completed Bid Schedule, bound in the Bidding Documents,
properly signed, providing the Owner a proposed cost for providing the services required in the
Bidding Documents.
Section 2. Preparation of Bids
2.1 The Bids must be submitted on the standard form herein furnished by the Owner (pages
15 - 29 as bound in these Bidding Documents). By submitting a Bid, Bidder acknowledges and
agrees that it shall execute the Agreement in the form attached hereto and incorporated herein.
The Bidder shall complete the Bid and shall sign the Bid correctly. The Bid may be rejected if it
contains any omission, alteration of form, conditional bid or irregularities of any kind. Bids must
be submitted on www.collierqov.net/bid
Section 3. Bid Deposit Requirements
3.1 No Bid shall be considered or accepted unless at the time of Bid filing the same shall be
accompanied by a cashier's check, a cash bond posted with the County Clerk, a certified check
payable to Owner on some bank or trust company located in the State of Florida insured by the
Federal Deposit Insurance Corporation, or Bid Bond, in an amount not less than 5% of the
bidder's maximum possible award (base bid plus all add alternates) (collectively referred to
herein as the "Bid Deposit"). The Bid Deposit shall be retained by Owner as liquidated damages
if the Successful Bidder fails to execute and deliver to Owner the unaltered Agreement, or fails
to deliver the required Performance and Payment Bonds or Certificates of Insurance, all within
ten (10) calendar days after receipt of the Notice of Award. Bid Bonds shall be executed by a
corporate surety licensed under the laws of the State of Florida to execute such bonds, with
5
Construction Services Agreement: Revised 02132017
conditions that the surety will, upon demand, forthwith make payment to Owner upon said bond.
Bid Deposits of the three (3) lowest Bidders shall be held until the Agreement has been
executed by the Successful Bidder and same has been delivered to Owner together with the
required bonds and insurance, after which all three (3) Bid Deposits shall be returned to the
respective Bidders. All other Bid Deposits shall be released within ten (10) working days of the
Bid Opening. No Bid including alternates, shall be withdrawn within one hundred and twenty
(120) days after the public opening thereof. If a Bid is not accepted within said time period it
shall be deemed rejected and the Bid Deposit shall be returned to Bidder. In the event that the
Owner awards the contract prior to the expiration of the one hundred twenty (120) day period
without selecting any or all alternates, the Owner shall retain the right to subsequently award to
the Successful Bidder said alternates at a later time but no later than one hundred twenty (120)
days from opening, unless otherwise agreed by the Procurement Director and the Successful
Bidder.
3.2 The Successful Bidder shall execute two (2) copies of the Agreement in the form
attached and deliver same to Owner within the time period noted above. The Owner shall
execute all copies and return one fully executed copy of the Agreement to Successful Bidder
within thirty (30) working days after receipt of the executed Agreement from Successful Bidder
unless any governmental agency having funding control over the Project requires additional
time, in which event the Owner shall have such additional time to execute the Agreement as
may be reasonably necessary.
Section 4. Right to Reject Bids
4.1 The Owner reserves the right to reject any and all Bids or to waive informalities and
negotiate with the apparent lowest, responsive and responsible Bidder to such extent as may be
necessary for budgetary reasons.
Section 5. Signing of Bids
5.1 Bids submitted by a corporation must be executed in the corporate name by the
president, a vice president, or duly authorized representative. The corporate address and state
of incorporation must be shown below the signature.
5.2 Bids by a partnership must be executed in the partnership name and signed by a
general partner whose title must appear under the signature and the official address of the
partnership must be shown below said signature.
5.3 If Bidder is an individual, his or her signature shall be inscribed.
5.4 If signature is by an agent or other than an officer of corporation or general partner of
partnership, a properly notarized power of attorney must be submitted with the Bid.
5.5 All Bids shall have names typed or printed below all signatures.
5.6 All Bids shall state the Bidder's contractor license number.
5.7 Failure to follow the provisions of this section shall be grounds for rejecting the Bid as
irregular or unauthorized.
6
Construction Services Agreement: Revised 02132017
Any Bid may be withdrawn at any time prior to the hour fixed in the Legal Advertisement for the
opening of Bids, provided that the withdrawal is requested in writing, properly executed by the
Bidder and received by Owner prior to Bid Opening. The withdrawal of a Bid will not prejudice
the right of a Bidder to file a new Bid prior to the time specified for Bid opening.
No Bid shall be accepted that fails to be submitted prior to the time specified in the Legal
Advertisement.
8.1 No interpretation of the meaning of the plans, specifications or other Bidding Documents
shall be made to a Bidder orally. Any such oral or other interpretations or clarifications shall be
without legal effect. All requests for interpretations or clarifications shall be in writing and
addressed on the County's Online Bidding System to be given consideration. All such requests
for interpretations or clarification must be received as directed in the Online Bidding System
instructions and prior to the Bid opening date. Any and all such interpretations and
supplemental instructions shall be in the form of written addendum which, if issued via the
Online Bidding System at their respective email addresses furnished for such purposes no later
than three (3) working days prior to the date fixed for the opening of Bids. Such written
addenda shall be binding on Bidder and shall become a part of the Bidding Documents.
8.2 It shall be the responsibility of each Bidder to ascertain, prior to submitting its Bid, that it
has received all addenda issued and it shall acknowledge same in its Bid.
8.3 As noted in the Legal Advertisement, attendance by all bidders at the Pre -Bid
Conference is non -mandatory.
Section 9. Examination of Site and Contract Documents
9.1 By executing and submitting its Bid, each Bidder certifies that it has:
a. Examined all Bidding Documents thoroughly;
b. Visited the site to become familiar with local conditions that may in any manner affect
performance of the Work;
C. Become familiar with all federal, state and local laws, ordinances, rules, and regulations
affecting performance of the Work; and
d. Correlated all of its observations with the requirements of the Bidding documents.
No plea of ignorance of conditions or difficulties that may exist or conditions or difficulties that
may be encountered in the execution of the Work pursuant to these Bidding Documents as a
result of failure to make the necessary examinations and investigations shall be accepted as an
excuse for any failure or omission on the part of the Successful Bidder, nor shall they be
accepted as a basis for any claims whatsoever for extra compensation or for an extension of
time.
7
Construction Services Agreement: Revised 02132017
9.2 The Owner will make copies of surveys and reports performed in conjunction with this
Project available to any Bidder requesting them at cost; provided, however, the Owner does not
warrant or represent to any Bidder either the completeness or accuracy of any such surveys
and reports. Before submitting its Bid, each Bidder shall, at its own expense, make such
additional surveys and investigations as may be necessary to determine its Bid price for the
performance of the Work within the terms of the Bidding Documents. This provision shall be
subject to Section 2.3 of the General Conditions to the Agreement.
Section 10. Material Requirements
It is the intention of these Bidding Documents to identify standard materials. When space is
provided on the Bid Schedule, Bidders shall specify the materials which they propose to use in
the Project. The Owner may declare any Bid non-responsive or irregular if such materials are
not specifically named by Bidder.
Section 11. Bid Quantities
11.1 Quantities given in the Bid Schedule, while estimated from the best information
available, are approximate only. Payment for unit price items shall be based on the actual
number of units installed for the Work. Bids shall be compared on the basis of number of units
stated in the Bid Schedule as set forth in the Bidding Documents. Said unit prices shall be
multiplied by the bid quantities for the total Bid price. Any Bid not conforming to this requirement
may be rejected. Special attention to all Bidders is called to this provision, because if conditions
make it necessary or prudent to revise the unit quantities, the unit prices will be fixed for such
increased or decreased quantities. Compensation for such additive or subtractive changes in
the quantities shall be limited to the unit prices in the Bid. Subsequent to the issuance of a
notice to proceed, the Project Manager and the Successful Bidder shall have the discretion to
re -negotiate any unit price(s) where the actual quantity varies by more than twenty-five percent
(25%) from the estimate at the time of bid.
11.2 Alternate Bid Pricing: In the event that alternate pricing is requested, it is an
expressed requirement of the bid invitation to provide pricing for all alternates as listed. The
omission of a response or a no -bid or lack of a submitted price may be the basis for the
rejection of the submitted bid response.
Section 12. Award of Contract
12.1 Any prospective bidder who desires to protest any aspect(s) or provision(s) of the bid
invitation (including the form of the bid documents or bid procedures) shall file their protest with
the Procurement Director prior to the time of the bid opening strictly in accordance with Owner's
then current procurement ordinance and policies.
12.2 Statement of Award: The Award of Contract shall be issued to the lowest, responsive
and responsible Bidder determined by the base bid, and any, or all, selected alternates, and the
Owner's investigations of the Bidder. In determining the lowest, responsive and responsible
bidder, the Owner shall consider the capability of the Bidder to perform the contract in a timely
and responsible manner. When the contract is awarded by Owner, such award shall be
evidenced by a written Notice of Award, signed by a Procurement professional of the Owner's
Procurement Services Division or his or her designee and delivered to the intended awardee or
mailed to awardee at the business address shown in the Bid.
12.3 Award recommendations will be posted on the Procurement Services Division Web Site.
Award of Contract will be made by the Board of County Commissioners in public session. Any
a
Construction Services Agreement: Revised 02132017
actual or prospective bidder who desires to formally protest the recommended contract award
must file a notice of intent to protest with the Procurement Director within two (2) calendar days
(excluding weekends and holidays) of the date that the recommended award is posted. Upon
filing of said notice, the protesting party will have five (5) days to file a formal protest, said
protest to strictly comply with Owner's then current procurement ordinance and policies. A copy
of the procurement ordinance is available at;
http://www.colliergov.net/index.aspx?page=762
12.4 For Bidders who may wish to receive copies of Bids after the Bid opening, The Owner
reserves the right to recover all costs associated with the printing and distribution of such
copies.
12.5 Certificate of Authority to Conduct Business in the State of Florida (FL Statute
607.1501)
In order to be considered for award, firms must be registered with the Florida Department of State
Divisions of Corporations in accordance with the requirements of Florida Statute 607.1501 and
provide a certificate of authority (www.sunbiz.org/search.html) prior to execution of a contract. A
copy of the document may be submitted with the solicitation response and the document number
shall be identified. Firms who do not provide the certificate of authority at the time of response
shall be required to provide same within five (5) days upon notification of selection for award. If
the firm cannot provide the document within the referenced timeframe, the County reserves the
right to award to another firm.
Section 13. Sales Tax
13.1 The Successful Bidder acknowledges and agrees that Owner may utilize a sales tax
savings program and the Successful Bidder agrees to fully comply, at no additional cost to
Owner, with such sales tax savings program implemented by the Owner as set forth in the
Agreement and in accordance with Owner's policies and procedures.
Section 14. Exclusion of County Permits in Bid Prices
14.1 To ensure compliance with Section 218.80, F.S., otherwise known as "The Public Bid
Disclosure Act", Collier County will pay the Contractor for all Collier County permits and fees
applicable to the Project, including license fees, permit fees, impact fees or inspection fees
applicable to this Work through an internal budget transfer(s). Hence, bidders shall not include
these permittfee amounts in their bid offer. However, the Successful Bidder shall retain the
responsibility to initiate and complete all necessary and appropriate actions to obtain the
required permits other than payment for the items identified in this section. Owner will not be
obligated to pay for any permits obtained by Subcontractors.
14.2 The Successful Bidder shall be responsible for procuring and paying for all necessary
permits not issued by Collier County pursuant to the prosecution of the work.
Section 15. Use of Subcontractors
15.1 To ensure the Work contemplated by the Contract Documents is performed in a
professional and timely manner, all Subcontractors performing any portion of the work on this
Project shall be "qualified" as defined in Collier County Ordinance 2013-69, as amended,
meaning a person or entity that has the capability in all respects to perform fully the Agreement
9
Construction Services Agreement: Revised 02132017
requirements and has the integrity and reliability to assure good faith performance. A
Subcontractor's disqualification from bidding by the Owner, or other public contracting entity
within the past twelve months shall be considered by the Owner when determining whether the
Subcontractors are "qualified."
15.2 The Owner may consider the past performance and capability of a Subcontractor when
evaluating the ability, capacity and skill of the Bidder and its ability to perform the Agreement
within the time required. Owner reserves the right to disqualify a Bidder who includes
Subcontractors in its bid offer which are not "qualified' or who do not meet the legal
requirements applicable to and necessitated by this Agreement.
15.3 The Owner may reject all bids proposing the use of any subcontractors who have been
disqualified from submitting bids to the Owner, disqualified or de -certified for bidding purposes
by any public contracting entity, or who has exhibited an inability to perform through any other
means.
15.4 Notwithstanding anything in the Contract Documents to the contrary, the Bidder shall
identify the subcontractor(s) it intends to use for the categories of work as set forth in the List of
Subcontracts attached hereto, said list to be submitted with its bid. Bidders acknowledge and
agree that the subcontractors identified on the list is not a complete list of the subcontractors to
be used on the Project, but rather only the major subcontractors for each category of Work as
established by Owner. Bidders further acknowledge that once there is an Award of Contract,
the Successful Bidder shall identify, subject to Owner's review and approval, all the
subcontractors it intends to use on the Project. Once approved by Owner, no subcontractor
shall be removed or replaced without Owner's prior written approval.
Section 16. Prohibition of Gifts
No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan,
fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III,
Florida Statutes, Collier County Ethics Ordinance No. 2004-05, as amended, and County
Administrative Procedure 5311. Violation of this provision may result in one or more of the
following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm
from contact with County staff for a specified period of time; b. Prohibition by the individual
and/or firm from doing business with the County for a specified period of time, including but not
limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any contract
held by the individual and/or firm for cause.
Section 17. Lobbyinq
All firms are hereby placed on NOTICE that the Board of County Commissioners does
not wish to be lobbied, either individually or collectively about a project for which a firm
has submitted a response. Firms and their agents are not to contact members of the County
Commission for such purposes as meeting or introduction, luncheons, dinners, etc. During the
process, from solicitation closing to final Board approval, no firm or their agent shall contact any
other employee of Collier County in reference to this solicitation, or the vendors response, with
the exception of the Procurement Director or his designee(s). Failure to abide by this provision
may serve as grounds for disqualification for award of this contract to the firm.
Section 18. Public Entity Crimes
By its submitting a Bid, Bidder acknowledges and agrees to and represents it is in compliance
with the terms of Section 287.133(2)(x) of the Florida Statutes which read as follows:
10
Construction Services Agreement: Revised 02132017
°A person or affiliate who has been placed on the convicted vendor list
following a conviction for a public entity crime may not submit a bid,
proposal, or reply on a contract to provide any goods or services to a
public entity; may not submit a bid, proposal, or reply on a contract with a
public entity for the construction or repair of a public building or public
work; may not submit bids, proposals, or replies on leases of real property
to a public entity'; may not be awarded or perform work as a contractor,
supplier, subcontractor, or consultant under a contract with any public
entity; and may not transact business with any public entity in excess of
the threshold amount provided in s. 287.017 for CATEGORY TWO for a
period of 36 months from the date of being placed on the convicted vendor
list."
11
Construction Services Agreement: Revised 02132017
Full Name of Bidd
Main Business Ad
Place of Business
CONSTRUCTION BID
WA W
• 1101V Ip ,i,
Cocohatchee River Park Marina Renovations
BID NO.
Telephone No. -�J r�',�° ,:: €. 1 t >�,/ Fax
State Contractor's License #a
State of Florida Certificate of Authority Document Number i� i� ," ,it: r✓' ° ~ ��
Federal Tax Identification Number
DUNS # vq-- �t (.'f J;' CCR# 0 -*6'--;1 Mi Cage Code
To: BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA
(hereinafter called the Owner)
The undersigned, as Bidder declares that the only person or parties interested in this Bid as
principals are those named herein, that this Bid is submitted without collusion with any other
person, firm or corporation; that it has carefully examined the location of the proposed Work, the
proposed form of Agreement and all other Contract Documents and Bonds, and the Contract
Drawings and Specifications.
Bidder proposes, and agrees if this Bid is accepted, Bidder will execute the Agreement included
in the Bidding Documents, to provide all necessary machinery, tools, apparatus and other means
of construction, including utility and transportation services necessary to do all the Work, and
furnish all the materials and equipment specified or referred to in the Contract Documents in the
manner and time herein prescribed and according to the requirements of the Owner as therein
set forth, furnish the Contractor's Bonds and Insurance specified in the General Conditions of the
Contract, and to do all other things required of the Contractor by the Contract Documents, and
that it will take full payment the sums set forth in the following Bid Schedule:
Unit prices shall be provided in no more than two decimal points, and in the case where
further decimal points are inadvertently provided, rounding to two decimal points will be
conducted by Procurement Services Division staff.
12
Construction Services Agreement: Revised 02132017
9:13:06 AM 511612017
Licensee Details
Licensee Information
Name: MID LO, BRIAN LOUIS (Primary Name)
MARINE CONTRACTING GROUP, INC. (DBA Name)
Main Address: 8260 PASCAL DRIVE
PUNTA GORDA Florida 33950
County: CHARLOTTE
License Mailing:
License Location:
License Information
License Type:
Rank:
License Number:
Status:
Licensure Date:
Expires:
Special Qualifications
Construction Business
Marine Specialty
Contractor
Alternate Names
View Ljggn5g-CgpjpjgjpLt
Certified Specialty Contractor
Cert Specialty
SCC131151730
Current,Active
01/26/2016
08/31/2018
Qualification Effective
01/26/2016
01/26/2016
e FL 32399 :: Email! Customer _Contact Center : : Custorrier Contact Center: 850.487.1395
I he State of Florida is an AA/EEO employer. RtjyacyStatement
Under Florida lavi, email addresses are public records It you do not want your email address released in response to a public records
request; do not send electronic 'nail to this entity. Instead, contact the office by phone or by traditional mail. If you have any
Mjest,ons, please, contact 85OA87,1395, 'Pursuant to Section 455.275(1), Florida Statutes, effective October 1, 2012, licensees
licensed under Chapter 455, F.S, rnust provide. the Departrnenl: with an email address if they have one.. The emails provided may be
-e -. re
used for official communication with the licensee. However email addresses are Public. -cord, If you do riot wish to supply a personal
address, please, provide the Department with an email address'which can be made available to the public, Please see our ChU"r
A
Aad, page to determine if you are affected by this change,
https://www.myfloridalicense.com/LicenseDetail.asp?SID=&id=9DO7D6B I BC89BBACD... 5/16/2017
Detail by Entity Name
...............
Get' irmril of St_v,° . / Divissoro I-earcr,hecends / DtalSyocumn;_`unher
, c /
Mail by Entity
Florida Profit Corporation
MARINE CONTRACTING GROUP, INC.
Filing information
Document Number
FEI/EIN Number
Date Filed
State
Status
Last Event
Event Date Filed
Event Effective Date
Principal Address
8260 PASCAL DRIVE
PUNTA GORDA, FL 33950
Changed: 01/11/2016
Mailing Address
8260 PASCAL DRIVE
PUNTA GORDA, FL 33950
P98000071228
65-0869775
08/12/1998
FL
ACTIVE
AMENDED AND RESTATED ARTICLES
09/22/2009
NONE
Changed: 01/11/2016
Registered Agent Name & Address
MIDOLO, BRAIN L
8260 PASCAL DRIVE
PUNTA GORDA, FL 33950
Name Changed: 05/04/2004
Address Changed: 01/11/2016
Officer/Director Detail
Name & Address
Title TSD
MIDOLO, BRIAN L
8260 PASCAL DRIVE
PUNTA GORDA, FL 33950
Page 1 of 2
http://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=Entity... 5/10/2017
Detail by Entity Mame
Title PD
MIDOLO, BRUCE A
8260 PASCAL DRIVE
PUNTA GORDA, FL 33950
&nnual Reports
UAL -REP ORT
Report Year
Filed Date
2015
01/20/2015
2016
01/11/2016
2017
02/10/2017
Document Images
UL,i 10i2Ji_i:._-.-_ANN
UAL -REP ORT
61111,,201E --
ANNUAL REPORT
O1011'20'5, —ANN
UAL REPORT
0 1120/20 14 --
AN N UAL. R E PO RT
1)3125,,2( 3 --
ANNUAL I R E PO R'T
IJ212?+/20,,2-A�=P�UAL
REPORT
I31i14/2(i 1 --
ANNUAL REPORT
r)21t91 'l a --
ANNUA,L REPORT
6'x/2312009 --ANNUAL REPORT
04,'ZfV2008 -- ANNUAL REPOR.I..
(4/2312007 -.. ANNU&I.-REPOR1..
G�104 z�04-,-_ANNUAL REPORT.
Gg12_gr2 03-.ANNU,L_RE_PORT
03106,'20;02 -- ANNUAL REPORT
o,im v2(01 -- ANNUA€_ REPORT
03123/201)()— ANNUAL R E PO RI
ANNUAL REPORT
02,'2.51:9'39 -- ANWJAL. REPORT
0811[,, 919& - TOoir�=Lr Profit
View image in PDF' `ormat I
View image in PDF wi-mat
View Image in PDF format
`✓iew image in PDF forn'ei
Vie•.v image in PDF format
Vie•.v imc:gein PDF format
Viev image in PDF format
I Vi¢vd image, m PDF format I
I View rnag(; in PDP 'ormat I
View irnagc in PDF `cimat
View image in PDF fni-mat
Via,, mage in PDFferrrat
Vie•., image a, PDF terrr:at
7',o
[—V.,
iew wags in PDF?�rmat
CView image in P€:)F' format
View image in PDF forrr:at
View image in PDF format
Vis•.v image in PDF Gxrnet
Vie•.v irrag«: in PDF fcrnat
View image in PDF format
View image in PDF Poi rat
F777,7,7- in PDP format
Page 2 of 2
http://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=Entity... 5/10/2017
BID SCHEDULE
efirorhatc,
Bid No. 17-7125
To Follow this Page"
13
Construction Services Agreement: Revised 02132017
May 1, 2017 17-7125 Bid Tabulation
Project: Cocohatchee River Park Marina Renovations
Description: Marina Repair and Replacment Costs
Contractor: MARINE CONTRACTING GROUP
(TEiV1DES CB�PT10l� „ >; �,..�:'.�': --
>
.:":..," QUNTtTY-;
;;,._.,UN,IT
LUNtP�UNtpsT .,
1.1-1.2
MOBILIZATION & DEMOBILIZATION
1
LS
$65,000.00
2.1-2.3
DEMOLITION & DISPOSAL
1
LS
$80,000.00
3.1-3.3, 3.6-3.7
FIXED DOCK (EXCLUDING PILES)
1
LS
$336,200.00
3.4-3.5
DOCK PILES
1
LS
$271,000.00
4.2
FIRE EXTINGUISHERS
1
LS
$30,000.00
4.4
WATER SERVICE
1
LS
$56,000.00
4.5
ELECTRICAL SERVICE
1
LS
$170,000.00
4.7
SECURITY GATES
1
LS
$5,000.00
4.8
POWER PEDESTALS
1
LS
$49,025.00
5.1-5.4
MOORING PILES
1
LS
$17,000.00
6.1
SEAWALL CAP REPLACEMENT (ZONE 3 AND 4)
1
LS
$58,275.00
6.1
TIE-BACK/DEADMAN REPLACEMENT (ZONE 3)
1
LS
$5,000.00
6.1
EXCAVATION OF TIE -BACK ZONE 5
1
LS
$9,000.00
7.1
SIDEWALKS
1
Ls
$15,000.00
12.0
PROJECT SIGN
1
LS
$2,500.00
FDOT 401-70-1
ISPALL REPAIR
1
LS
$75,000.00
FDOT 411-2
ICRACK REPAIR
1
LS
$50,000.00
BASE BID TOTAL
' $1,294U00'
OWNERS ALLOWANCE
$100,000
TOTAL BIDI
$1,394,000
ADD ALTERNATE
ITEM NO.::.:.40�11
05T P T
BOAT RAMP REPLACEMENT
$975,000:00
T{il N0. ; 1.._ - ,
1 •• ' 1• '
:' .�: ITEM RCRIP.TIC3(
�;: QUANTITY
'.,,NT:CST
„-,
LO
VESSEL RELOCATION* (Based on 1-8 EA)
8
LS
$1,500.00
2.0
ADDITIONAL CLEATS"* (Based on 2-15 EA)
15
LS
$125.00
6.1
TIE -BACK REPAIR - (Based on 2-10 EA)
10
ea
;, $2,000.00
FDOT 401-70-1
ADDITIONAL SPALL REPAIR - (Based on 10-50 CF)
50
cf
$300.00
FDOT 411-2
JADDITIONAL CRACK REPAIR - (Based on 10-50 LF)
50
If
$150.00
The Contractor shall submit a proposed schedule that provides the estimated number of days to replace each zone and a
total time schedule to complete the entire project.
*Provide a unit price per vessel for Contractor to move a renter's vessel from its slip to a temporary mooring location as
determined by the County, safely secure said vessel until the permanent slip has been completely renovated, and then to
replace said vessel in its permanent slip and safely secure it. The temporary mooring location will involve double breasting
**Provide a unit price per cleat to furnish and install additional 12" HDG Cleats, Model # 040112 by Sea -Dog Marine, or
approved equal.
Bridging i"L(
5863 Sccova Reser vs cll-t"le
Naples - F L .3 1
Tel. (239) 216 -MO
"i So I I'l I i
May 4, 2017
Margaret A. Bishop, P,E,
Senior Project Manager
Facilities Managetnent Deparunerrt
Collier lier Coi
ol-I -trity Governrnent
3299 Tainia.mi Trail East
Maples, FL 31 I 12
RE: A -ward. Recomrneadation, - Cocohatchee River Park M-awinfi
Dear Ms. Bishop:
BRIDGING
vW SOLUTIONS
Bridging Solutions, LLC (BSLLC) has completed our review of the bids received for the Cocohatchee River Park
Marina project and is pleased to provide Collier County (County) the following recommendation, The project
included a Base Bid for the repair and replacement of the marina, an Add Alternate Bid for the boat ramp
replacement and Unit Prices for unforeseen iterns. The County received three (3) bids for the Cocohatchee River
Park Marina project. However, the bid received from Greg, Orek 11 Marine Construction was deemed unresponsive.
The two (2) remaining Base Bids ranged froni $1,494,000 to S1,595,603. The Add Alternate Bids ranged from
$17500 to $231,000; and Unit Prices for unforeseen items ranged from $49,232 to $56,375. Provided attached is
a SLIn-irnary of the Base Bids, Add Alternate Bids and Unit Prices.
Marine Contracting Group, Inc. (MCG) is the apparent low bidder with a Base Bid of $1,494,000; a bid of S 175,000
for Add Afternate; and a bid of $56,3 )75 For Unit Prices. MCG sbid is the lowest total bid. The project design Learn
has past experience working with MCG and consider them qualified for this type of work.
Based on the above information, Bridging Solutions, LLC recommends Marine Contracting GrOUP,hic, be awarded
the Cocohatchee River Park Marina project for the Base Bic.) an)ounl of $1,494,000.
Please contact me at 813-767..0538 if you have any questions or connnents.
Respectfully,
BRIDGING SOLUTIONS, LLC
CZ
Rolando Corsa, PE
Project Manager
We design bridges 10 fit YOUr site and budget.
MATERIAL MANUFACTURERS
THIS FORM MUST BE COMPLETED ORBID SHALL BEDEEMED NON-RESPONSIVE
All Bidders yhoU confirm by signature that they will provide the manufacturers and materials
outlined in this Bid npaoificat|ons, including compliance with Florida Statute 255.20 to provide
|umber. Umber and other forest products produced and manufactured in the State of Florida an
long aothe price, fitness and quality are equal, Exceptions (when equals are acceptable) may ba
requested by completing the Material Manufacturer Exception List below. If an exception fora
manufacturer and/or material is proposed and listed below and is not approved by
EnAinoer/prcjec±Monager. Bidder shall furnish the manufacturer named in the specification.
Acceptance of this form does not constitute acceptance of material proposed on this list.
Complete and sign section ,4[>R B.
Section /\(Acceptance of all manufactures and materials in Bid specifications)
On behalf of my firm, | confirm that we will use all manufacturers and materials as
specifically outlined in the Bid specifications.
Section B(Exception requested LoBid specifications manufacturers and materials)
EXCEPTION MATERIAL EXCEPTION MANUFACTURER
1
2.
3.
4,
5.
Please insert additional pages as necessary.
14
Construction Services Agreement: Revised 021320 r
LIST OF O> SUBCONTRACTORS
r
The undersigned states that the following is a list of the proposed subcontractors for the major
categories outlined in the requirements of the Bid specifications.
The undersigned acknowledges its responsibility for ensuring that the Subcontractors for the
major categories listed herein are "qualified" (as defined in Ordinance 2017-08 and Section 15 of
Instructions to Bidders) and meet all legal requirements applicable to and necessitated by the
Contract Documents, including, but not limited to proper licenses, certifications, registrations and
insurance coverage. The Owner reserves the right to disqualify any Bidder who includes non-
compliant or non-qualified Subcontractors in its bid offer. Further, the Owner may direct the
Successful Bidder to remove/replace any Subcontractor, at no additional cost to Owner, which is
found to be non-compliant with this requirement either before or after the issuance of the Award
of Contract by Owner. (Attach additional sheets as needed). Further, the undersigned
acknowledges and agrees that promptly after the Award of Contract, and in accordance with the
requirements of the Contract Documents, the Successful Bidder shall identify all Subcontractors
it intends to use on the Project. The undersigned further agrees that all Subcontractors
subsequently identified for any portion of work on this Project must be qualified as noted above.
Compan ) y
r
Signature
a5�i3s'
15
Construction Services Agreement: Revised 02132017
STATEMENT OF EXPERIENCE OF BIDDER
The Bidder is required to state below what work of similar magnitude completed within the last
five (5) years is a judge of its experience, skill and business standing and of its ability to conduct
the work as completely and as rapidly as required under the terms of the Agreement.
Project and Location Reference (include phone # or email
address
16
Construction Services Agreement: Revised 02132017
�a'1�1
Owner/Engineer Contact, Phone
Project, Owner, Address
Scope of Work
contractValue
Completion
Project Mgr.
Number Fax, E-mail
Lalshley Park Marina
Marian Pace
New Seawall 16' concrete panel with
$2,192,000.00
City of Punta Gorda
900 W. Henry St
Punta Gorda, Florida 33950
P: 941-575-3348 F: 941-575-3340
mPace@pgorda.us
King pile, New marina construction of
80+ slips, Floating and fixed dock
construction
March 2007
Bruce Midolo/
Suzette Baxter
Project, Owner, Address
Owner/Engineer Contact, Phone
Number. Fax E-mail
Scope of Work
Initial Contract, Final
Value
Completion
PrdJect Mgr -
Florida Marine Laboratory
Florida Fish and Wildlife Services
Layton, Florida
John Hunt
305-289-2330
John, Flunt@,MyEWC.com
Shoreline restoration, seawall
installation, dredge, and dock
installation
$1,174,805.00
npril-zoos
Bruce Midolo/
JR Elmer
$1,300,000.00
Project, Owner, Address
Owner]Engineer Contact, Phone
Number Fax E-mailScope
of Work
Initial Contract, Final
Value
Completion
Prdject Mgr.
Port LaBelle Marina
Port LaBelle Dock, LLC
Walter Ferguson
305-856-4235
Construction of fixed wood docks
with finger piers, fend off piles, and
dredging
Bruce Midolo/
JR Elmer
$1.298;539.00
June =2007
Protect, Owner, Address
Owner/Engineer Contact, Phone
Number Fax E-mail
Scope of Work
Initial Contract, Final
Value
Completion
Protect Mgr.
Punta Gorda Seawalls
City of Punta Gorda
906 W. Henry Street
Catherine Miller
941-575-5071
Concrete seawall replacement,
100,000 LF, on-going, Approximately
5,000-10,000 per year
Varies
Bruce Midolo/
Suzette Baxter
$1,500,000.00
On -Going
annually
Since 1997
Punta Garda, Florida 33950
Project, Owner, Address
Owner/Engineer Contact, Phone
I Number Fax E-mail
Scope of Work
Initial Contract, Fina(
Value
Completion
Project Mgr.
Tampa Harbour Yacht Club
Tampa Harbout Devel., LLCIYCOA
17501 Harbour Point Drive
April Miller
239-489-2969
Fax 239-489-2996
Reconfiguration including removallexisting marina, and rebuilding of
pilings and docks
$354,000.00
Bruce Midolo/
Suzette Baxter
$446,275.00
Oct. -2008
For! Myers, A 33908
Project, Owner, Address
Owner/Engineer Contact, Phone
Number, Fax E-mail
Scope of Work
Initial Contract, Final
Value
Completion
Project Mgr.
Naples Powerboat Squadron Marina
Naples Powerboat Marina
Jim Fisher
239-261-8878
Removal of hurricane damaged
structure, reconstruction of dock,
seawall, roof, pilings, and slips
Bruce Midolo/
Suzette Baxter
$271,596.60
_ _.
March -2008
Project, Owner, Address
Owner)Engineer Contact, Phone
Number Fax E-mailScope
of Work
eom ace value
Completion
Project Mgr.
Isles Yacht Club
Dave Gerdet
Reconstruction of collapsed dock &
$206,185.00
Sept. - 2006
isles Yacht Club, Inc.
941-505-8620
pilings, including
Bruce Mido#o/
fingerdocks,walkways, fuel dock, and
JR Elmer
water pedestals
Project, Owner, Address
Owner/Engineer Contact, Phone
Number Fax_.E-mall
Scope of Work
contract Value
Completion
Project Mgr.
Sea isles Condominiums
Condo Assoc. of Sea Isles, Inc
Punta Gorda, A
Robert McHugh
941-639-4823
Demolition and reconstruction of
existing finger docks and support
pilings
Bruce Midolo/
Suzette Baxter
$140,000.00
Sept.- 2008
Project, Owner, Address
OwnedEngineer Contact, Phone
Number, Fax, E-mail
Scope of Work
p
Contract Value
Completion
Project Mgr.
Ocean Club at Port Canaveral
Dream Harbors LLC
909 10th Street South, #105
Naples, FI 34102
Frank Donahue
239-643-7855
Fax 239-643-7859
emerald ladyyacht(cbaol.com
Pile driving, rebuild of pier and
auch pad, and seawall, slipways
in floating dock configuration.
Bruce Midolo/
Suzette Baxter
$597,540.00
April -2008
Project, Owner, Address
Owner/Engineer Contact, Phone
Number, Fax, E-mail
Scope of Work
Initial Contract,
Final Value
Completion
Project Mgr.
Vanderbuilt Surf Colony
VSC Rec. & Maintenance Assoc.
Turrell, Hail and Associates
Michael Kurtz
Replace seawall and install wood
$272,372.00
Bruce Midolo/
$289,940.00
Aril -2009
11 Biuebill Ave.
239-643-0144
walkway and multiple docks
Suzette Baxter
Naples, Florida 34108
fax 239-643-6632
Project, Owner, Address
J
Scope of Work
Initial Contract,
Final Value
Completion
Project Mgr,
Ballast Point Pier
Sten Anderson
Rehabilitation offishing pier,
$996,200.00
$947,630.00
April -2009
City of Tampa
813-393-7886
including replacement of decking,
Bruce Midolo
5212 Interbay Blvd,
Tampa, FI 33602
railings, benches, fish cleaning
stations, and shelter
�a'1�1
Project, Owner, Address
Owner
Scope of Work
Contract Value
Completion
Project Mgr.
Cocohatchee Deck
Removal and replacement of
$87,385.00
Collier County BOCC
Collier County
decking, pile removal, and
Apr-09
Suzette Baxter
Vanderbuilt Dr. Naples
replacement of wood stair with
concrete stairs
Project, Owner, Address
Owner
Scope of Work
Contract Value
Completion
Project Mgr.
Harborwalk-Gilchrist Park
City of Punta Gorda, Florida
Construction of small boat launch
400 West Retta Esplanade
ramp, and replacement of seawall
$239,30.6.50
Jul-11
Bruce Midolo/
Punta Gorda, FI 33950
Suzette Baxter
Project, Owner, Address
Owner
Scope of Work
Contract Value
Completion
Project Mgr.
Nathan Benderson Aquatic Center
Benderson Development
2500 Honore Ave
7978 Cooper Creek Blvd. #100
Construction of boat ramp
Aug. 2012
Bruce Midolo(
Sarasota, FI 34240
University Park, Fl 34201
$429,196.00
Suzette Baxter
Project, Owner, Address
Owner
Scope of Work
Contract Value
Completion
Project Mgr.
Lettuce Lake Park
Arcadia, FI
Desoto County, FI
201 East Oak St. 11201
Construction of boat ramp, floating
$302,175.00
Feb. 2014
Bruce Midolo/ JR
Desoto County
Arcadia, Fl 34266
dock system, and park
improvements including site work,
Eimer
Project, Location
Owner
Scope of Work
Contract Value
Completion
Project Mgr.
Punta Gorda Hotel Wtft. Harborwalk
Constuction of Waterfront
Retta EsplanadelUS 41
City of Punta Gorda
Harborwalk. Seawall, Bridge,
$556,520.04
Sep. 2013
Punta Gorda, Florida
Retaining walls, side walks,
JR Elmer
railings, pavers, lighting,
landscaping
Project, Location
Owner/Engineer Contact, Phone
Scope of Work
Contract Value
Completion
Project
Number, Fax, E-mail
Mana er
Indies West Seawalls
Indies West Association, Inc.
2200 Gulf Shore Blvd. N.
Reuben Clarson, PE
installation of 525LF Vinyl
$636,860.80
Suzette Baxter
Naples. FI 34102
750 94th Ave. N Ste.213
Seawall and Cap System
Nov. 2015
St, Petersburg, FI 33702
727-578-9542
Project, Location
Owner Contact Information
Scope of Work
Contract Value
Completion
Project
Mana er
Punta Gorda Harborwalk - it
City of Punta Gorda - Marion Pace
Removal and Replacement of
400 W. Retta Esplanade
Punta Gorda, FI 33950
326 W. Marion Ave
Punta Gorda, FI 33950
1251 LF of concrete seawall with
$979,469.00
Dec. 2015
Michael J. Kurtz
cap system along with Pedestrian
941-575-3348 F.941-575-3340
walkway
moace onpgorda.us
Project
Project, Location
Owner Contact Information
Scope of Work
Contract Value
Completion
Mana er
City of Sarasota
Bird Key Bridges Seawall Repairs
Bird Key, Sarasota, FI
1565 First St
Sarasota, FI 34236
Replacement of Seawalls under
$734,869.00
Nov. 2016
Michael J. Kurtz
four main bridges on Bird Key
Richard Winder
941-365-2200
Project
Project, Location
Owner Contact Information
Scope of Work
Contract Value
Completion
Mena er
Cayo Costa/Jug Creek
Department of Environmental Protectio
Lee County
3900 Commonwealth Blvd. MS 520
Dredging of two canal systems,
Tallahassee, FI 32399
Replacement of seawall, docks
$355,838.00
Aug. 2016
Suzette Baxter
Alyssa Del.ong
and boat ramp
850-245-2466
Page 2 of 2
Bidder acknowledges that included in the various items of the bid and in the Total Bid Price are costs for
complying with the Florida Trench Safety Act (90-96, Laws of Florida) effective October 1, 1990. The Bidder
further identifies the cost to be summarized below:
Trench Safety
Measure
.(Description_)
1.
2.
3.
4.
5.
Units of Unit
(Measure Quantity)
L( F,SY)
TOTAL$
Unit Extended
Cost Cost
Failure to complete the above may result in the Bid being declared non-responsive,
17
Construction Services Agreement: Revised 02132017
ie, --r County
Administrative Services Department
pmcuran.ent Services Division
Immigration Law Affidavit Certification
Solicitation: 17-7125 Cocohatchee River Park Marina Renovations
This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with formal
Invitations to Bid (ITB's) and Request for Proposals (RFP) submittals. Further, Vendors / Bidders are required to enroll
in the E -Verify program, and provide acceptable evidence of their enrollment, at the time of the submission of the
vendor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E -Verify Company Profile
page or a copy of the fully executed E -Verify Memorandum of Understanding for the company. Failure to include this
Affidavit and acceptable evidence of enrollment in the E -Verify program, may, deem the Vendor / Bidder's
proposal as non-responsive.
Collier County will not intentionally award County contracts to any vendor who knowingly employs unauthorized alien
workers, constituting a violation of the employment provision contained in 8 U.S.C. Section 1324 a(e) Section 274A(e)
of the Immigration and Nationality Act ("INA").
Collier County may consider the employment by any vendor of unauthorized aliens a violation of Section 274A (e) of the
INA. Such Violation by the recipient of the Employment Provisions contained in Section 274A (e) of the INA shall be
grounds for unilateral termination of the contract by Collier County.
Vendor attests that they are fully compliant with all applicable immigration laws (specifically to the 1986 Immigration Act
and subsequent Amendment(s)) and agrees to comply with the provisions of the Memorandum of Understanding with E -
Verify and to provide proof of enrollment in The Employment Eligibility Verification System (E -Verify), operated by the
Department of Homeland Security in partnership with the Social Security Administration at the time of submission of the
Vendor's / Bidder's proposal. j
Company Name
Print Name
Signature
State of t' Jrl r( A
County of. C,kwtnR:i
(
The fore goin instr meat was signed and acknowledged before me this 12day of �f , 20 ! , by
r� C� i r� 0 � C) (print or type name) who has produced % Y
(rltl
of ide tificat� and mber) as identification.
n' r* PNS, JENNIFER FAIHMKS
otary P` blic Signature yea' `:'a= MycomMISSIONGFF9:i6212
�/�,� EXPIRES: November 75, 2019
/r/) l ✓V ti / 11§it i." lauded Thru Wary Public Underwriters
Printed Name of Notary Public
Notary Commission Number/Expiration
The signee of this Affidavit guarantees, as evidenced by the sworn affidavit required herein, the truth and accuracy of
this affidavit to interrogatories hereinafter made.
18
Construction Services Agreement: Revised 02132017
a
3:3 k7i 10N •64:r a*43 LN 111]
ARTICLE I
This Memorandum of Understanding (MOU) sets forth the points of agreement between the
Department of Homeland Security (DHS) and Marine Contracting Group, Inc. (Employer)
regarding the Employer's participation in the Employment Eligibility Verification Program (E -
Verify). This MOU explains certain features of the E -Verify program and enumerates specific
responsibilities of DHS, the Social Security Administration (SSA), and the Employer. E -Verify is
a program that electronically confirms an employee's eligibility to work in the United States after
completion of the Employment Eligibility Verification Form (Form 1-9). For covered government
contractors, E -Verify is used to verify the employment eligibility of all newly hired employees and
all existing employees assigned to Federal contracts or to verify the entire workforce if the
contractor so chooses.
Authority for the E -Verify program is found in Title IV, Subtitle A, of the Illegal Immigration
Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Pub. L. 104-208, 110 Stat. 3009, as
amended (8 U.S.C. § 1324a note). Authority for use of the E -Verify program by Federal
contractors and subcontractors covered by the terms of Subpart 22.18, "Employment Eligibility
Verification", of the Federal Acquisition Regulation (FAR) (hereinafter referred to in this MOU as
a "Federal contractor with the FAR E -Verify clause") to verify the employment eligibility of
certain employees working on Federal contracts is also found in Subpart 22.18 and in Executive
Order 12989, as amended.
FUNCTIONS TO BE PERFORMED
A. RESPONSIBILITIES OF SSA
1. SSA agrees to provide the Employer with available information that allows the Employer to
confirm the accuracy of Social Security Numbers provided by all employees verified under this
MOU and the employment authorization of U.S. citizens.
2. SSA agrees to provide to the Employer appropriate assistance with operational problems that
may arise during the Employer's participation in the E -Verify program. SSA agrees to provide
the Employer with names, titles, addresses, and telephone numbers of SSA representatives to
be contacted during the E -Verify process.
3. SSA agrees to safeguard the information provided by the Employer through the E -Verify
program procedures, and to limit access to such information, as is appropriate by law, to
individuals responsible for the verification of Social Security Numbers and for evaluation of the
E -Verify program or such other persons or entities who may be authorized by SSA as governed
Page 1 of 13 1 E -Verify MOU for Employer i Revision Date 09/01/09 www.dhs.gov/E-Verify
•.' • . • -JM
Nationality Act (INA) and Federal criminal laws, and to administer Federal contracting
requirements.
7. DHS agrees to provide a means of automated verification that is designed (in conjunction
with SSA verification procedures) to provide confirmation or tentative nonconfirmation of
employees' employment eligibility within 3 Federal Government work days of the initial inquiry.
8. DHS agrees to provide a means of secondary verification (including updating DHS records as
may be necessary) for employees who contest DHS tentative nonconf rmations and photo non -
match tentative nonconfirmations that is designed to provide final confirmation or
nonconfirmation of the employees' employment eligibility within 10 Federal Government work
days of the date of referral to DHS, unless DNS determines that more than 10 days may be
necessary. In such cases, DHS will provide additional verification instructions.
1. The Employer agrees to display the notices supplied by DHS in a prominent place that is
clearly visible to prospective employees and all employees who are to be verified through the
system.
2. The Employer agrees to provide to the SSA and DHS the names, titles, addresses, and
telephone numbers of the Employer representatives to be contacted regarding E -Verify.
3. The Employer agrees to become familiar with and comply with the most recent version of the
E -Verify User Manual.
4. The Employer agrees that any Employer Representative who will perform employment
verification queries will complete the E -Verify Tutorial before that individual initiates any queries.
A. The Employer agrees that all Employer representatives will take the refresher tutorials
initiated by the E -Verify program as a condition of continued use of E -Verify.
B. Failure to complete a refresher tutorial will prevent the Employer from continued use
of the program.
5. The Employer agrees to comply with current Form 1-9 procedures, with two exceptions:
• If an employee presents a "List B" identity document, the Employer agrees to only
accept "List B" documents that
c)ntain a photo. (List B documents identified in 8 C.F.R. § 274a.2(b)(1)(B)) can be
presented during the Form 1-9
process to establish identity.) If an employee objects to the photo requirement for
religious reasons, the Employer
should contact E -Verify at 888-464-4218.
• If an employee presents a DHS Form 1-551 (Permanent Resident Card) or Form 1-766
(Employment Authorization Document) to complete the Form 1-9, the Employer agrees to
make a photocopy of the document and to retain the photocopy with the employee's
Form 1-9. The photocopy must be of sufficient quality to allow for verification of the photo
Page 3 of 13 1 E -Verify MOU for Employer i Revision Date 09/01/09 www.dhs.gov/E-Verify
-
uses the E -Verify system for any purpose other than as authorized by this MOU, the Employer
may be subject to appropriate legal action and termination of its access to SSA and DHS
information pursuant to this MOU.
9. The Employer agrees to follow appropriate procedures (see Article Ill. below) regarding
tentative nonconfirmations, including notifying employees in private of the finding and providing
them written notice of the findings, providing written referral instructions to employees, allowing
employees to contest the finding, and not taking adverse action against employees if they
choose to contest the finding. Further, when employees contest a tentative nonconfirmation
based upon a photo non -match, the Employer is required to take affirmative steps (see Article
III.B. below) to contact DHS with information necessary to resolve the challenge.
10. The Employer agrees not to take any adverse action against an employee based upon the
employee's perceived employment eligibility status while SSA or DHS is processing the
verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a.1(1))
that the employee is not work authorized. The Employer understands that an initial inability of
the SSA or DHS automated verification system to verify work authorization, a tentative
nonconfirmation, a case in continuance (indicating the need for additional time for the
government to resolve a case), or the finding of a photo non -match, does not establish, and
should not be interpreted as evidence, that the employee is not work authorized. In any of the
cases listed above, the employee must be provided a full and fair opportunity to contest the
finding, and if he or she does so, the employee may not be terminated or suffer any adverse
employment consequences based upon the employee's perceived employment eligibility status
(including denying, reducing, or extending work hours, delaying or preventing training, requiring
an employee to work in poorer conditions, refusing to assign the employee to a Federal contract
or other assignment, or otherwise subjecting an employee to any assumption that he or she is
unauthorized to work) until and unless secondary verification by SSA or DHS has been
completed and a final nonconfirmation has been issued. If the employee does not choose to
contest a tentative nonconfirmation or a photo non -match or if a secondary verification is
completed and a final nonconfirmation is issued, then the Employer can find the employee is not
work authorized and terminate the employee's employment. Employers or employees with
questions about a final nonconfirmation may call E -Verify at 1-888-464-4218 or OSC at 1-800-
255-8155 or 1-800-237-2515 (TDD).
11. The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section
274B of the INA, as applicable, by not discriminating unlawfully against any individual in hiring,
firing, or recruitment or referral practices because of his or her national origin or, in the case of a
protected individual as defined in section 27413(a)(3) of the INA, because of his or her
citizenship status. The Employer understands that such illegal practices can include selective
verification or use of E -Verify except as provided in part D below, or discharging or refusing to
hire employees because they appear or sound "foreign" or have received tentative
nonconfirmations. The Employer further understands that any violation of the unfair immigration -
related employment practices provisions in section 274E of the INA could subject the Employer
to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject
the Employer to back pay awards, compensatory and punitive damages. Violations of either
section 274B of the INA or Title VII may also lead to the termination of its participation in E -
Page 5 of 13 1 E -Verify MOU for Employer I Revision Date 09/01/09 www.dhs.gov1E-Verify
whether or not assigned to the contract. Once the Employer begins verifying new hires, such
verification of new hires must be initiated within 3 business days after the date of hire. Once
enrolled in E -Verify as a Federal contractor with the FAR E -Verify clause, the Employer must
initiate verification of employees assigned to the contract within 90 calendar days from the time
of enrollment in the system and after the date and selecting which employees will be verified in
E -Verify or within 30 days of an employee's assignment to the contract, whichever date is later,
d. Employers that are already enrolled in E -Verify at the time of a contract award but are
not enrolled in the system as a Federal contractor with the FAR E -Verify clause: Employers
enrolled in E -Verify for 90 days or more at the time of a contract award must use E -Verify to
initiate verification of employment eligibility for new hires of the Employer who are working in the
United States, whether or not assigned to the contract, within 3 business days after the date of
hire. Employers enrolled in E -Verify as other than a Federal contractor with the FAR E -Verify
clause, must update E -Verify to indicate that they are a Federal contractor with the FAR E -
Verify clause within 30 days after assignment to the contract. If the Employer is enrolled in E -
Verify for 90 calendar days or less at the time of contract award, the Employer must, within 90
days of enrollment, begin to use E -Verify to initiate verification of new hires of the contractor
who are working in the United States, whether or not assigned to the contract. Such verification
of new hires must be initiated within 3 business days after the date of hire. An Employer
enrolled as a Federal contractor with the FAR E -Verify clause in E -Verify must initiate
verification of each employee assigned to the contract within 90 calendar days after date of
contract award or within 30 days after assignment to the contract, whichever is.later.
e. Institutions of higher education, State, local and tribal governments and sureties:
Federal contractors with the FAR E -Verify clause that are institutions of higher education (as
defined at 20 U.S.C. 1001(a)), State or local governments, governments of Federally recognized
Indian tribes, or sureties performing under a takeover agreement entered into with a Federal
agency pursuant to a performance bond may choose to only verify new and existing employees
assigned to the Federal contract. Such Federal contractors with the FAR E -Verify clause may,
however, elect to verify all new hires, and/or all existing employees hired after November 6,
1986. The provisions of Article II.D, paragraphs 1.a and 1.b of this MOU providing timeframes
for initiating employment verification of employees assigned to a contract apply to such
institutions of higher education, State, local and tribal governments, and sureties.
f. Verification of all employees; Upon enrollment, Employers who are Federal contractors
with the FAR E -Verify clause may elect to verify employment eligibility of all existing employees
working in the United States who were hired after November 6, 1986, instead of verifying only
new employees and those existing employees assigned to a covered Federal contract. After
enrollment, Employers must elect to do so only in the manner designated by DHS and initiate E -
Verify verification of all existing employees within 180 days after the election.
g, Form 1-9 procedures for existing employees of Federal contractors with the FAR E -
Verify clause: Federal contractors with the FAR E -Verify clause may choose to complete new
Forms 1-9 for all existing employees other than those that are completely exempt from this
process. Federal contractors with the FAR E -Verify clause may also update previously
completed Forms 1-9 to initiate E -Verify verification of existing employees who are not
completely exempt as long as that Form 1-9 is complete (including the SSN), complies with
Page 7 of 131 E -Verify MOU for Employer I Revision Date 09/01/09 www.dhs.gov/E-Verify
t
-Verl
Company [D Number: 367 882
determines that more than 10 days is necessary. The Employer agrees to check the E -Verify
system regularly for case updates.
4. The Employer agrees not to ask the employee to obtain a printout from the Social Security
Number database (the Numident) or other written verification of the Social Security Number
from the SSA.
1. If the Employer receives a tentative nonconfirmation issued by DHS, the Employer must print
the tentative nonconfirmation notice as directed by the E -Verify system and provide it to the
employee so that the employee may determine whether he or she will contest the tentative
nonconfirmation. The Employer must review the tentative nonconfirmation with the employee in
private.
2. If the Employer finds a photo non -match for an employee who provides a document for which
the automated system has transmitted a photo, the employer must print the photo non -match
tentative nonconfirmation notice as directed by the automated system and provide it to the
employee so that the employee may determine whether he or she will contest the finding. The
Employer must review the tentative nonconfirmation with the employee in private.
3. The Employer agrees to refer individuals to DHS only when the employee chooses to contest
a tentative nonconfirmation received from DHS automated verification process or when the
Employer issues a tentative nonconfirmation based upon a photo non -match. The Employer will
determine whether the employee contests the tentative nonconfirmation as soon as possible
after the Employer receives it.
4. If the employee contests a tentative nonconfirmation issued by DHS, the Employer wit]
provide the employee with a referral letter and instruct the employee to contact DHS through its
toll-free hotline (as found on the referral letter) within 8 Federal Government work days.
5. If the employee contests a tentative nonconfirmation based upon a photo non -match, the
Employer will provide the employee with a referral letter to DHS. DHS will electronically transmit
the result of the referral to the Employer within 10 Federal Government work days of the referral
unless it determines that more than 10 days is necessary. The Employer agrees to check the E -
Verify system regularly for case updates.
6. The Employer agrees that if an employee contests a tentative nonconfirmation based upon a
photo non -match, the Employer will send a copy of the employee's Form 1-551 or Form 1-766 to
DHS for review by:
• Scanning and uploading the document, or
• Sending a photocopy of the document by an express mail account (paid for at
employer expense),
7. If the Employer determines that there is a photo non -match when comparing the photocopied
List B document described in Article II.C.5 with the image generated in E -Verify, the Employer
must forward the employee's documentation to DHS using one of the means described in the
preceding paragraph, and allow DHS to resolve the case.
Page 9 of 13 1 E -Verify MDU for Employer I Revision Date 09/01/09 www.dhs.gov/E-Verify
D, Nothing in this MOU is intended, or should be construed, to create any right or benefit,
substantive or procedural, enforceable at law by any third party against the United States, its
agencies, officers, or employees, or against the Employer, its agents, officers, or employees.
E, Each party shall be solely responsible for defending any claim or action against it arising out
of or related to E -Verify or this MOU, whether civil or criminal, and for any liability wherefrom,
including (but not limited to) any dispute between the Employer and any other person or entity
regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by
the Employer.
F. The Employer understands that the fact of its participation in E -Verify is not confidential
information and may be disclosed as authorized or required by law and DHS or SSA policy,
including but not limited to, Congressional oversight, E -Verify publicity and media inquiries,
determinations of compliance with Federal contractual requirements, and responses to inquiries
under the Freedom of Information Act (FOIA).
G. The foregoing constitutes the full agreement on this subject between DHS and the Employer,
H. The individuals whose signatures appear below represent that they are authorized to enter
into this MOU on behalf of the Employer and DHS respectively.
Page 11 of 13 1 E -Verify MOU for Employer i Revision Date 09/01/09 www.dhs.gov/E-Verify,
Company ID Number: 367882
North American Industry
Systems
Code: '237
_....
Classification y
ssification S
..._.-.........-._.....-_..._........._-.... -- 37
Administrator:
- Number of Employees: 120 to 99
-.____...._..__..._....__...........---------
_.__._-__........._..__._..--_____.._.__..___..__------
_..._.._-_.__..__T_._-....__..._...._._.._____._---...____
Number of Sites Verified I
i for.
II
re you verifying for more than 1 site? If yes, please provide the
i
he number of sites verified fo'-
in each State:
o FLOR[DA 1 sites)
� I
Information relating to the Program Administrator(s) for your Company on policy
questions or operational problems:
Name:
Brian L Midolo
Telephone Number:
(941) 505 - 0221 Pas Number; (941) 505 - 0320
E-mail Address:
blmidolo@—tmcgfl.com
Name:
Suzette Baxter
Telephone Number:
(9.11) 505 -0221 Fax Number: (941) 505 - 0320
E-mail Address:
sb:txter(almcglt.com
Page 13 of 13 1 E -Verify MOU for Employer ( Revision Date 09/01109 www.dhs.gov/E-Verify
At w
Administrafive Services DepaitTient
Procurement Services DNision
COLLIER COUNTY SOLICITATIONS SUBSTITUTE W- 9
Request for Taxpayer Identification Number and Certification
In accordance with the Internal Revenue Service regulations, Collier County is required to collect the following
information for tax reporting purposes from individuals and companies who do business with the County (including
social security numbers if used by the individual or company for tax reporting purposes). Florida Statute
119.071(5) require that the county notify you in writing of the reason for collecting this information, which will be
used for no other purpose than herein stated. Please complete all information that applies to your business and
return with your quote or proposal,
1. General Information (provide all information)
Taxpayer Name I. :A) " r
/�_�-,-�.�:'-moi- .,t:• �r� �'�;—
(as shown on income tax return)
Business Name
(if different from taxpaXer name 1
Address ntsir3'_ �(_i� City
. t
State r'� Zip
ephone
order Information Remit l Payment Information
1
Address X _ L410 ,f 6 .--� j Address Y ! '� a"`A-5 b'z
City ,.i"; State X Zip 2�-;C. ') City State Zip
FAX Ci C? FAX
��-
4 f� �� ' U � .,� ✓`✓ �` � c':� 5'- � � � z.. c_>
Email �Ali a L ra lrf� ���171'L� ���a L�"r'- Email fr9'1,' Cir>d0
2. Company Status (check only one)
Individual l Sole Proprietor
-Corporation
_Partnership
_Tax Exempt (Federal income tax-exempt entity
Limited Liability Company
under Internal Revenue Service guidelines IRC
501 (c) 3)
__� ^ Enter the tax classification
D = Disregarded Entity, C = Corporation, P = Partnershipj
3. Taxpayer Identification Number (for tax reporting purposes only)
Federal Tax Identification Number (TIN) 61 °S
(Vendors who do not have a TIN, will be required to provide a social security number prior to an award of the contract.)
4. Sign and Date Form
Certification: Underpenaltigg of perjury, I certify t the information shown on this form is correct to my knowledge.
Signature
rC `
Title 1'73:h)_/,
Phone Number
19
Services Agreement: Revised 02132017
I certify Rom the records of this office that MARINE CONTRACTING
GROUP, INC. is a coV I poration organized Linder the laws of the State of Florida,
filed on August 12,
1§98.
The document number of this corporation is P98000071228.
I further certify that said corporation has paid all fees due this office through
December 31, 2004, that its most recent annual report/uniform business report
was filed on May 4, 2004, and its status is active.
I further certify that said corporation has not filed Articles of Dissolution.
GR2E022 (2-03)
Given under my hand and the
Great Seal of the State of Florida
at Tallahassee, the Capitol, this the
Nineteenth day of May, 2004
btate
-Iretarp of 6
Upon notification that its Bid has been awarded, the Successful Bidder will execute the Agreement form
attached to the Bidding Documents within ten (10) calendar days and deliver the Surety Bond or Bonds
and Insurance Certificates as required by the Contract Documents. The bid security attached is to become
the property of the Owner in the event the Agreement, Insurance Certificates and Bonds are not executed
and delivered to Owner within the time above set forth, as liquidated damages, for the delay and additional
expense to the Owner, it being recognized that, since time is of the essence, Owner will suffer financial
loss if the Successful Bidder fails to execute and deliver to Owner the required Agreement, Insurance
Certificates and Bonds within the required time period. In the event of such failure, the total amount of
Owner's damages, will be difficult, if not impossible, to definitely ascertain and quantify. It is hereby agreed
that it is appropriate and fair that Owner receive liquidated damages from the Successful Bidder in the
event it fails to execute and deliver the Agreement, Insurance Certificates, and Bonds as required
hereunder. The Successful Bidder hereby expressly waives and relinquishes any right which it may have
to seek to characterize the above noted liquidated damages as a penalty, which the parties agree
represents a fair and reasonable estimate of Owner's actual damages at the time of bidding if the
Successful Bidder fails to execute and deliver the Agreement, Insurance Certificates, and Bonds in a timely
manner.
Upon receipt of the signed and approved agreement and Purchase Order, the undersigned proposes to
commence work at the site within five (5) calendar days from the commencement date stipulated in the
written Notice to Proceed unless the Project Manager, in writing, subsequently notifies the Contractor of a
modified (later) commencement date. The undersigned further agrees to substantially complete all work
covered by this Bid within One Hundred Twenty (R 20) consecutive calendar days, computed by excluding
the commencement date and including the last day of such period, and to be fully completed to the point
of final acceptance by the Owner within Thirty (30) consecutive calendar days after Substantial
Completion, computed by excluding commencement date and including the last day of such period.
Respectfully Submitted:
State of
County of r>l
,/3 being first duly sworn on oath
deposes and says that the Bidder on the above Bid is organized as indicated and that all statements herein
made are made on behalf of such Bidder and that this deponent is authorized to make them.
17--) ' rr, -7 y ,40' / , also deposes and says that it has
examined and carefully prepared its Bid from the Bidding Documents, including the Contract Drawings and
Specifications and has checked the same in detail before submitting this Bid; that the statements contained
herein are true and correct.
(a) Corporation
The Bidder is a corporation organized and existing under the laws of the State of which
operates under the legal name of .:�,� l ���'>�,7�`� �=>;s%z>..,h _:' and the full
names of its officers are as follows: T
President F-:A�M-d r,
Secretary 147ilI-4 L t
Treasurer ' ){%'r3-
✓1"h Aok
Manager.
20
Construction Services Agreement: Revised 02132017
The
the compa
(b) Co -Partnership
is authorized to sign construction bids and contracts for
a..certified copy
le)
The Bidder is a co -partnership consisting of individual partners whose full names are as follows:
The co -partnership does business underthe legal name of:
(c) Individual
The Bidder is an individual whose full name is and if operati
under a trade name, said trade name is
Complete for information contained in (a) Corporation, (b) Co -Partnership or (c) Individual from previo
page.
DATED
Witness
Witness
!U �/(r�')i•G�l� ! F�'r'%!,!,��%:'11n/ _ L.` `'!f, "v.tl t.•v'('\i,'.
Legal Entity ;f
Name of Bidder (Typ° )
Sig re
_`� A .
Title '
21
Construction Services Agreement: Revised 02132017
STATE OF :e j��'L s��Ia_
COUNTY OF
1A,
The ,foregoing instrument was acknowledged before me this � day of J1 %j ' 2017, by
j \ i i j s
c;-1 1- �`�, '4-:1 1,1:as � 1 %` �!/" ,r�- �„�'� 1 of
7 J
Aa/�v� ��,,_ corporation, on behalf
corporation. He/she is Ors6nallf known to me or has produced
as identification and did (did not) take an oath.
My Commission Expires: �L� �0,1ao ��/'atvi
(gnat of N tary)
JENNIFER FAIRBANKS
j,y4• G ''>s,i c
MY COMMISSION FF 936212 DAME: 1 '/� dfl d i �/ t /� ft 1.
£�y EXPiRES: november 16, 2o1s (Legibly Printed)
9onded Thou Notary Public Underwrite
(AFFIX OFFICIAL SEAL)
Notary Public, State of aoiicik
Commission No.:
of the
22
Construction Services Agreement: Revised 02132017
fcs:�
KNOW ALL MEN BY THESE PRESENTS, that we Marine Contracting Group, Inc., 8260 Pascal
Drive, Punta Gorda, FL 33950 (941) 505-0221 (herein after called the Principal) and
North American Specialty lnsurance Company. 650 Elm 5t, Manchester, NH 03101 (603) 644-6600 , (herein
called the Surety), a corporation chartered and existing under the laws of the State of
. New.Hampsl-dre ...with its principal offices in the city of Manchester -- - and authorized to -
do business in the State o� Florida are held and firmly bound unto the
Collier County Board of County oMMsr Bn hereinafter called the Owner), in
Maples, FT '1411 � ( )
the full and ---Just' sum of 5%of Bid dollars
($ ) good and lawful money of the United States of America, to be paid upon
demand of the Owner, to which payment well and truly to be made, the Principal and the Surety
bind themselves, their heirs, and executors, administrators, and assigns, jointly and severally and
firmly by these presents.
Whereas, the Principal is about to submit, or has submitted to the Owner, a Bid for furnishing all
labor, materials, equipment and incidentals necessary to furnish, install, and fully complete the
Work on the Project known as Bid Pio. 17-7125 Cocohatchee River Park marina Renovations,
NOW, THEREFORE, if the Owner shall accept the Bid of the PRINCIPAL and the PRINCIPAL shall
enter into the required Agreement with the Owner and within ten days after the date of a written
Notice of Award in accordance with the terms of such Bid, and give such bond or bonds in an
amount of 100% the total Contract Amount as specified in the Bidding Documents or Contract
Documents with good and sufficient surety for the faithful performance of the Agreement and for
the prompt payment of labor, materials and supplies furnished in the prosecution thereof or, in the
event of the failure of the PRINCIPAL to enter into such Agreement or to give such bond or bonds,
and deliver to Owner the required certificates of insurance, if the PRINCIPAL shall pay to the
OBLIGEE the fixed sum of $ 2,636.00 noted above as liquidated damages, and not as a
penalty, as provided in the Bidding Documents, then this obligation shall be null and void, otherwise
to remain in full force and effect.
IN TESTIMONY Thereof, the Principal and Surety have caused these presents to be duly signed
and sealed this 19th day of April 2017.
Countersigned
Local Resident Producing Agent for
Principal
(Seal)
Surety
YY 111W1ll J. 1 dIA11G1, r Liviudy-in-Fac(Seal)
Florida Resident Agent
23
Construction Services Agreement: Revised 02132017
Vgm
NAS SURETY GROUP
NORTH AMERICAN SPECIALTY INSURANCE COMPANY
WASHINGTON INTERNATIONAL INSURANCE COMPANY
WESTPORT INSURANCE CORPORATION
GENERAL POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS, THAT North American Specialty Insurance Company, a corporation duty organized and existing colder
laws of the State of New Hampshire, and having its principal office in the City of Manchester, New Hampshire and Washington International Insurance
Company a corporation organized and existing under the laws of the State of New I-Iampshire and having its principal office in the City of Sehaumbur-,
Illinois, and Westport Insurance Corporation, organized under the laws of the State of M1SSollrl, and having its principal office in the City of Overland
Park, Kansas each does hereby make, constitute and appoint:
WILLTAivt1, PALMER, J. CORY BROAMAY, STEVEN I -L F46M, JULIE- A. nARSON, PATRICtA D. POST and,10DY M. TIFT
JOINTLY OR SEVERALLY
Its true and lawful Attorneys) -in -Fact, to nnalCC- execute, seal and deliver, for and on its behalf and as its act and deed, bonds or other writings
obligatory in the nature ora bond on behalf of each of said Companies, as surety, on contracts of suretyship as are or may be required or permitted by
law, regulation, contract or otherwise, provided that no bond or undertaking or contract or suretyship executed under this authority shall exceeCI the
amount of ONE HUNDRED TWENTY FIVE MILLION (S 125,000,000.00) DOLLARS
This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of
Directors ofNorth American Specialty Insurance Company and Washington International Insurance Company at meetings duly called and held
on March 24, 2000 anti Westport Insurance Corporation by written consent of its Executive Committee dated July IS, 2011.
"RESOLVED, that any two of the President, any Senior Vice President, any Vice President, any Assistant Vice President,
the Secretary or any Assistant Secretary be, and each or any of them hereby is authorized to execute a Power of Attorney qualifying the attorney named
in the given Power of Attorney to execute on behalf of the Company bonds, undertakings and all contracts of surety, and that each or any of them
hereby is authorized to attest to the execution of any such Power of Attorney and to attach therein the seal of the Company; and it is
FURTHER RESOLVED, that the signature of such officers and the seal of the Company may be affixed to any such Power of Attorney or to any
certificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be
binding upon the Company when so affixed and in the future with regard to any bond, undertaking or contract of surety to which it is attached."
p1rALIITiY;N' r�
4�1po�o NA('��sL
\`\'1111\�'
i
\��
o
SEAL :n"
SEALZ
y 'Z, 1973 v;:m
•
9tis;cY t�`' �a�
�lkd "YAWS..",
//f/�
O7NIII101
—.
By
Steven P.: Anderson, Senior ce President u:uu
u -tort nternat ono isurance Cntnpany
& Senior Vice President of North Aatetiean Specilla' Insurance Compt"tY
C Senior Vice President of Westport h+snnmce Corporation
By 1 11 1
Alike A. no, Senior Vice President of Witshington htteruntionsl Insurance Coniptmy
$ SeniorVice President of Nm-th American Specialty Insunmcc Company
S Senior Vice President ofnVestport h+stvance Corporatlon
00 14
e a��
�E03d2t4til�'
IN WITNESS WHEREOF, North American Specialty Insurance Company, Washington International Insurance Company and Westport
Insurance Corporation have caused their official seals to be hereunto affixed, and these presents to be signed by their authorized officers this
this 21st day or_ October , 20 l6
North American Specialty Insurance Company
Washington International Insurance Company
State of Illinois Westport Insurance Corporation
County of Cook ss:
On this 21st day of October • 20 16, before me, a Notary Public personally appeared Steven R Anderson , Senior Vice President of
Washington International Insurance Company and Senior Vice President of North American Specialty Insurance Company and Senior Vi,:e President of
Westport Insurance Corporation and Michael A. Ito Senior Vice President of Washington International Insurance Company and Senior Vice President
ol'North American Specialty Insurance Company and Senior Vice President of Westport Insurance Corporation, personally known to me, who
being by me duty sworn, acknowledged that they signed the above Power of Attorney as officers of incl acknowledged said instrument to be the
voluntary act and deed of their respective companies.
OFFfCIAL SEAL
NOTARY PUBLIC, STATE OF ILLIN015
MY COMMISSION IXPIRES 12/04121)17 M. Kenny, Notary Public
I, Jeffrey Goldberg the duty elected Vice President and Assistant Secretary oi'North American Specialty Insurance Company, Washington
International Insurance Company and Westport Insurance Corporation do hereby certify that the above and foregoing is a true and correct copy ofa
Power of Attorney given by said North American Specialty Insurance Company, Washington International Insurance Company and Westport Insurance
Corporation which is still in full force and effect.
IN WITNESS WHEREOF, I have set my hand and affixed the seats of the Companies this l9th clay of' April 120 17
JerfiYy Gordbcig. Vice President C Assistant Sect e(or)• of Washirwton huernntiunal Insurance Company &
North Annericnn Sprciahy lacuranee Comping & Vice President S .Assistant Secretory of Westport Insurance Corporation
THIS SHEET MUST BE SIGNED BY VENDOR
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
Procurement Services Division
BIDDERS CHECK LIST
IMPORTANT: Please read carefully, sign in the spaces indicated and return with
your Bide
Bidder should check off each of the following items as the necessary action is completed:
1. The Bid has been signed.
2. The Bid prices offered have been reviewed.
3. The price extensions and totals have been checked.
4. Any required drawings, descriptive literature, etc. have been included.
5. Any delivery information required is included.
6. Immigration Affidavit completed and the company's E -Verify profile page or
memorandum of understanding
7. Certificate of Authority to Conduct Business in State of Florida and the County's
Substitute W9
8. If required, the amount of Bid bond has been checked, and the Bid bond or cashier's
check has been included.
9. Any addenda have been signed and included.
10. The Bid will be uploaded in time to be received no later than the specified opening date
and time, otherwise the Bid cannot be considered.
Bidder Name
Signature & Title
24
Construction Services Agreement: Revised: 02132017
3s,
County
Ad�r�ris��+�,�� :Servi+. �� zvision
LETMINOR-Mrom
Date: April 06, 2017
From: Jim Flanagan, Procurement Strategist
To: Interested Parties
Page 9 of I
Email: jimflanagan@colliergov.net
Telephone: (239) 252-8946
Subject: Addendum #1 – 17-7125 Cocohatchee River Park Marina Renovation
This addendum has been issued for the following items identifying changes, deletions, or
additions to the original solicitation document and bid schedule for the subject solicitation.
Changes and additions are identified with an underline and deletions have a strike -through.
CHANGES/ADDITIONS/DELETIONS:
> A non -mandatory pre-bid conference shall be held at the Project Site at Cocohatchee
River Park Marina, 13531 Vanderbilt Drive, Naples, FL at 9:00 a.m. LOCAL, TIME on
the 12th day .,f n —AI7n4 -79 1 1th daV of April 2017 at which time all prospective Bidders
may have questions answered regarding the Bidding Documents for this Project.
Please acknowledge receipt of thi ddendum with your bid proposal.
Signature—
Bidder
ignatureBidder t� �
If you require additional information please post a question on the Online Bidding site or contact
me using the above contact information.
Page 1 of 2
a:.
Email: jimflanagan@colliergov.net
Telephone: (239) 252-8946
� R ,
Date: April 27, 2017
From: Jim Flanagan, Procurement Strategist
To: Interested Parties
Subject: Addendum #2 — 17-7125 Cocohatchee River Park Marina Renovation
This addendum has been issued for the following items identifying changes, deletions, or
additions to the original solicitation document and bid schedule for the subject solicitation.
Changes and additions are identified with an underline and deletions have a strike -through.
> The contractor shall be responsible for re -supplying the electric and water utility services to
each phase (at most 8 slips at a time) as soon as the docks in that phase are complete and
useable.
> The County does not have as -built plans for the water and electric utilities at the marina. The
attached marked up plan labeled `Presumed Existing Utilities' is being provided by the County
to assist the contractor which was developed by County facilities staff. The contractor shall be
responsible for locating the existing control and routing of these utilities during construction.
The contractor shall reconnect plumbing to each new power pedestal. The County believes the
shut off valve for the water supply south of the entrance road is the valve located in the street.
> QUESTION: The Q&A mentions to take apart and re -hook up power to a total of 11 existing
boat lifts. Are all of the additional areas on page E-1 marked "BLP" going to be new boat lifts
that will need to be wired, or just designated spots for future boat lifts? If designated spots,
do they want a conduit pulled to a jbox in that area, or nothing? ANSWER: Boat lift power is
only to be restored at locations with existing boat lifts (11 locations). All other locations only
require power to the power pedestals. Conduit and junction box is not required at locations
that do not have existing boat lifts.
> In Section TS -6 Seawall Cap Replacement (Zones 3 and 4), delete the following sentence on
page 7, The GONTRAGTOR shall be paid the PF!Ge bid for Tie baGk4DeadMaR ReplaGernent
{ter Zone -3 &-4, and replace it with, The CONTRACTOR shall be paid the price bid for Tie-
back/Deadman Replacement (Zone 3) bid item if the full replacement of tie bars and deadman
is determined to be required in Zones 3 and 4 using contingency allowance funds.
17-7125 — Cocohatchee River Park Marina Renovation - Addendum #2 — 04-27-17
Page 2 of 2
The geotechnical report is attached.
> Revised Bid Schedule Issued for clarification
> Bid Schedule Clarifications
o Quantity and unit on all line items revised to a Lump Sum Cost per line item
o Owner's Allowance simplified and included below the bid total.
o Unit Prices for Unforseen Items — Contractors to provide unit prices for items of work
not part of the base bid or the alternate, and based on range of quantities as indicated
on revised Bid Schedule form.
Bid Schedule Clarification -- Indicate number of days required to complete each zone and a
total time schedule to complete the entire project.
Pre-bid Agenda Minutes and Sign -in sheets
o 17-7125 Pre -Bid 04-11-17 Agenda, Minutes and Sign -in -Sheets attached
9 Bidders Questions and Answers
o The Deadline for Bidder's Questions closed on Friday April 21. All Bidder's Questions
have been answered on-line through the Collier County Online Bidding System. Please
refer to Solicitation 17-7125 Cocohatchee River Park Marina Renovation — Q&A
Please acknowledge receipt of this Addendum with your bid proposal.
i
Signature 11,t), �L, Y�_ �zl�d0k,
Bidder
—
If you require additional information please post a question on the Online Bidding site or contact
me using the above contact information.
17-7125— Coco hatchee River Park Marina Renovation -Addendum #2 —04-27-17
Jer :I.
AdTS#nl tis�.i u'e St3+ '' F, I inion
V-LJrvl7 sin
E11-11 ► 1 -
Memorandum
Date: April 25, 2017
From: Jim Flanagan, Procurement Strategist
To; Interested Parties
Page 1 of 1
Email: jimflanagan@colliergov.net
Telephone: (239) 252-8946
Subject: Addendum #3 — 17-7125 Cocohatchee River Park Marina Renovation
This addendum has been issued for the following items identifying changes, deletions, or
additions to the original solicitation document and bid schedule for the subject solicitation.
Changes and additions are identified with an underline and deletions have a strike -through,
> Refer to 17-7125 Exhibit L — Supplemental Information — Proprietary Spec — Pedestal.pdf' in
the Bid Documents. Please use Chad Huff Pians (Sheets E-1 to E-3) for pedestal electrical
requirements. Please note: 50A receptacles and associated circuit breaker NOT required.
> Electrical Pians Clarification — All changes are clouded on Sheets E-1 to E-3.
o Load Calculations typo corrected and clouded on Sheets E-1 and E-2.
o Pedestal Matrix revised to include 20A receptacle on Side A.
> Clarifications of the Utilities are as follows:
o The use of HDPE instead of Schedule 80 PVC is acceptable underground, however it
is only accepted under the conditions at no additional cost to the County in comparison
to Schedule 80 PVC. Above ground utilities shall be Schedule 80 PVC only.
o Zone 5 is to be replaced as exists - Hose bib replacement at the fish cleaning station is
required.
o Water utilities shall be replaced to match existing - with a minimum main V run and
secondary taps as required to all power pedestals and hose bibbs.
> Correction to date of Addendum #2 — date should read April 24, 2017
Please acknowledge receipt of s Addendum with your bid proposal.
Signatur
Bidder (,V! J
If you require additional information please post a question on the Online Bidding site or contact
me using the above contact information.
17-7125 — Cocohatchee River Park Marina Renovation - Addendum #3 — 04-25-17
CONSTRUCTION AGREEMENT
THE BOARD OF COUNTY COMMISSIONERS OF COLLIER COUNTY, FLORIDA, ("Owner")
hereby contracts with Marine Contracting Group, Inc. ("Contractor") of 8620 Pascal Drive,
Punta Gorda, Florida 33950, a corporation, authorized to do business in the State of Florida, to
perform all work ("Work") in connection with Cocohatchee River Park Marina Renovations, Bid
No. 17-7125 ("Project"), as said Work is set forth in the Plans and Specifications prepared by
Bridging Solutions, LLC, the Engineer and/or Architect of Record ("Design Professional") and
other Contract Documents hereafter specified.
Owner and Contractor, for the consideration herein set forth, agree as follows:
Section 1. Contract Documents.
A. The Contract Documents consist of this Agreement, the Exhibits described in Section 6
hereof, the Legal Advertisement, the Bidding Documents and any duly executed and issued
addenda, Change Orders, Work Directive Changes, Field Orders and amendments relating
thereto. All of the foregoing Contract Documents are incorporated by reference and made a
part of this Agreement (all of said documents including the Agreement sometimes being referred
to herein as the "Contract Documents" and sometimes as the "Agreement" and sometimes as
the "Contract"). A copy of the Contract Documents shall be maintained by Contractor at the
Project site at all times during the performance of the Work.
B. Owner shall furnish to the Contractor one reproducible set of the Contract Documents
and the appropriate number of sets of the Construction Documents, signed and sealed by the
Design Professional, as are reasonably necessary for permitting.
Section 2. Scope of Work.
Contractor agrees to furnish and pay for all management, supervision, financing, labor,
materials, tools, fuel, supplies, utilities, equipment and services of every kind and type
necessary to diligently, timely, and fully perform and complete in a good and workmanlike
manner the Work required by the Contract Documents.
Section 3. Contract Amount.
In consideration of the faithful performance by Contractor of the covenants in this Agreement to
the full satisfaction and acceptance of Owner, Owner agrees to pay, or cause to be paid, to
Contractor the following amount (herein "Contract Amount"), in accordance with the terms
of this Agreement: One Million Three Hundred Ninety -Four Thousand and No
Cents (1,394,000.00).
Section 4. Bonds.
A. Contractor shall provide Performance and Payment Bonds, in the form prescribed in
Exhibit A, in the amount of 100% of the Contract Amount, the costs of which are to be paid by
Contractor. The Performance and Payment Bonds shall be underwritten by a surety authorized
to do business in the State of Florida and otherwise acceptable to Owner; provided, however,
the surety shall meet the requirements of the Department of the Treasury Fiscal Service,
"Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as
Acceptable Reinsurance Companies" circular. This circular may be accessed via the web at
www.fms.treas.gov/c570/c570.html#certified. Should the Contract Amount be less than
25
G
Construction Services Agreement: Revised 02132017
$500,000, the requirements of Section 287.0935, F.S. shall govern the rating and classification
of the surety.
B. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business is terminated in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5) calendar
days thereafter, substitute at its cost and expense another bond and surety, both of which shall
be subject to the Owner's approval.
Section 5. Contract Time and Liauidated Damaaes.
A. Time of Performance.
Time is of the essence in the performance of the Work under this Agreement. The
"Commencement Date" shall be established in the written Notice to Proceed to be issued by the
Project Manager, as hereinafter defined. Contractor shall commence the Work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor. Contractor shall achieve
Substantial Completion within One Hundred Twenty (120) calendar days from the
Commencement Date (herein "Contract Time"). The date of Substantial Completion of the
Work (or designated portions thereof) is the date certified by the Design Professional when
construction is sufficiently complete, in accordance with the Contract Documents, so Owner can
occupy or utilize the Work (or designated portions thereof) for the use for which it is intended.
Contractor shall achieve Final Completion within Thirty (30) calendar days after the date of
Substantial Completion. Final Completion shall occur when the Agreement is completed in its
entirety, is accepted by the Owner as complete and is so stated by the Owner as completed. As
used herein and throughout the Contract Documents, the phrase "Project Manager" refers to the
Owner's duly authorized representative and shall mean the Division Administrator or
Department Director, as applicable, acting directly or through duly authorized representatives.
B. Liquidated Damages in General.
Owner and Contractor recognize that, since time is of the essence for this Agreement, Owner
will suffer financial loss if Contractor fails to achieve Substantial Completion within the time
specified above, as said time may be adjusted as provided for herein. In such event, the total
amount of Owner's damages, will be difficult, if not impossible, to definitely ascertain and
quantify. Should Contractor fail to achieve Substantial Completion within the number of
calendar days established herein, Owner shall be entitled to assess, as liquidated damages, but
not as a penalty, Two Thousand Six Hundred Thirty Six Dollars ($2,636.00) for each
calendar day thereafter until Substantial Completion is achieved. Further, in the event
Substantial Completion is reached, but the Contractor fails to reach Final Completion within the
required time period, Owner shall also be entitled to assess and Contractor shall be liable for all
actual damages incurred by Owner as a result of Contractor failing to timely achieve Final
Completion. The Project shall be deemed to be substantially completed on the date the Project
Manager (or at his/her direction, the Design Professional) issues a Certificate of Substantial
Completion pursuant to the terms hereof. Contractor hereby expressly waives and relinquishes
any right which it may have to seek to characterize the above noted liquidated damages as a
penalty, which the parties agree represents a fair and reasonable estimate of the Owner's actual
damages at the time of contracting if Contractor fails to Substantially or Finally Complete the
Work within the required time periods.
26
Construction Services Agreement: Revised 02132017
C. Computation of Time Periods.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
D. Determination of Number of Days of Default.
For all contracts, regardless of whether the Contract Time is stipulated in calendar days or
working days, the Owner will count default days in calendar days.
E. Right of Collection.
The Owner has the right to apply any amounts due Contractor under this Agreement or any
other agreement between Owner and Contractor, as payment on such liquidated damages due
under this Agreement in Owner's sole discretion. Notwithstanding anything herein to the
contrary, Owner retains its right to liquidated damages due under this Agreement even if
Contractor, at Owner's election and in its sole discretion, is allowed to continue and to finish the
Work, or any part of it, after the expiration of the Contract Time including granted time
extensions.
F. Completion of Work by Owner.
In the event Contractor defaults on any of its obligations under the Agreement and Owner elects
to complete the Work, in whole or in part, through another contractor or its own forces, the
Contractor and its surety shall continue to be liable for the liquidated damages under the
Agreement until Owner achieves Substantial and Final Completion of the Work. Owner will not
charge liquidated damages for any delay in achieving Substantial or Final Completion as a
result of any unreasonable action or delay on the part of the Owner.
G. Final Acceptance by Owner.
The Owner shall consider the Agreement complete when the Contractor has completed in its
entirety all of the Work and the Owner has accepted all of the Work and notified the Contractor
in writing that the Work is complete. Once the Owner has approved and accepted the Work,
Contractor shall be entitled to final payment in accordance with the terms of the Contract
Documents.
H. Recovery of Damages Suffered by Third Parties.
Contractor shall be liable to Owner to the extent Owner incurs damages from a third party as a
result of Contractor's failure to fulfill all of its obligations under the Contract Documents.
Owner's recovery of any delay related damages under this Agreement through the liquidated
damages does not preclude Owner from recovering from Contractor any other non -delay related
damages that may be owed to it arising out of or relating to this Agreement.
Section 6. Exhibits Incorporated.
Exhibits Incorporated: The following documents are expressly agreed to be incorporated by
reference and made a part of this Agreement for Solicitation 17-7125 - Cocohatchee River Park
Marina Renovations.
Exhibit A: Performance and Payment Bond Forms
Exhibit B: Insurance Requirements
Exhibit C: Release and Affidavit Form
Exhibit D: Contractor Application for Payment Form
27
v
Construction Services Agreement: Revised 02132017
Exhibit E: Change Order Form
Exhibit F: Certificate OfSubstantial Completion Form
Exhibit G: Final Payment Checklist
Exhibit H: General Terms and Conditions
Exhibit 1: Supplemental Terms and Conditions
Exhibit J: Technical Specifications
Exhibit K: Permits
Exhibit L: Standard Details (if applicable)
Exhibit M: Plans and Specifications prepared byBridging Solutions, LLC
and identified as follows: 17-7125 Final P/3nS/17-7135 Final Technical
Specs aashown On Plan Sheets 1 through 28 and E1 -E3
Exhibit N: Contractor's List of Key Personnel
A. All notices required or made pursuant to this Agreement by the Contractor to the Owner
shall be shall be deemed duly served if delivered by U.S. Mail, E-mail or Facsimile, addressed
to the following:
Felicia Kirby, Associate Project Manager
Public Utilities Department/Facilities Management Division
3336TarnianniTrail East
Naples, Florida 34112
Telephone: (239)2S2'8O14
Email: FeliciaKirby(cD_colliergov.net
B. All notices required or made pursuant to this Agreement by Owner to Contractor shall be
nn3d8 in writing and shall be deemed duly served if delivered by U.S. KA8i|' E-mail Or Faosirni|8,
addressed to the following:
Bhan0Uco|o, Vice Preside rate Secretary
Marine Contracting Group, Inc.
82GOPascal Drive
Punta Gorda, Florida %3Q5O
Telephone: (B41)5O5-O221
FAX: (941)5O6-0320
Email:
C. Either party may change its above noted address by giving written notice to the other
party in accordance with the requirements of this Section.
Section 8. PUBLIC ENTITY CRIMES.
8.1 Bvits execution Cf this Contract, Construction Contractor acknowledges that ithas been
informed bvOwner ofthe terms of Section 287.133(2)/o) of the Florida Statutes which na8d as
"Aperson maffiliate who has been placed onthe convicted vendor list following
8 conviction for a public entity crime may not submit u bid on a contract to
provide any goods or services to a public entity for the construction or repair of a
public building or public work, may not submit bids on leases of real property to
@ public entity, may not be awarded or perform work as a contractor, supplier,
28
Construction Services Agreement: Revised mz1ouo 7
subcontractor, or consultant under a contract with any public entity in excess of
the threshold amount provided in s. 287.017 for CATEGORY TWO for a period
of 36 months from the date of being placed on the convicted vendor list."
Section 9. Modification.
No modification or change to the Agreement shall be valid or binding upon the parties unless in
writing and executed by the party or parties intended to be bound by it.
Section 10. Successors and Assigns.
Subject to other provisions hereof, the Agreement shall be binding upon and shall inure to the
benefit of the successors and assigns of the parties to the Agreement.
Section 11. Governing Law.
The Agreement shall be interpreted under and its performance governed by the laws of the
State of Florida.
Section 12. No Waiver.
The failure of the Owner to enforce at any time or for any period of time any one or more of the
provisions of the Agreement shall not be construed to be and shall not be a waiver of any such
provision or provisions or of its right thereafter to enforce each and every such provision.
Section 13. Entire Agreement.
Each of the parties hereto agrees and represents that the Agreement comprises the full and
entire agreement between the parties affecting the Work contemplated, and no other agreement
or understanding of any nature concerning the same has been entered into or will be
recognized, and that all negotiations, acts, work performed, or payments made prior to the
execution hereof shall be deemed merged in, integrated and superseded by the Agreement.
Section 14. Severability.
Should any provision of the Agreement be determined by a court to be unenforceable, such a
determination shall not affect the validity or enforceability of any other section or part thereof.
Section 15. Change Order Authorization.
The Project Manager shall have the authority on behalf of the Owner to execute all Change
Orders and Work Directive Changes to the Agreement to the extent provided for under the
Owner's procurement ordinance and policies and accompanying administrative procedures.
Section 16. Construction.
Any doubtful or ambiguous language contained in this Agreement shall not be construed against
the party who physically prepared this Agreement. The rule sometimes referred to as "fortius
contra proferentum" (pursuant to which ambiguities in a contractual term which appears on its
face to have been inserted for the benefit of one of the parties shall be construed against the
benefited party) shall not be applied to the construction of this Agreement.
Coo
29
Construction Services Agreement: Revised 02132017
Section 17. Order of Precedence
In the event of any conflict between or among the terms of any of the Contract Documents, the
terms of the Construction Agreement and the General Terms and Conditions shall take
precedence over the terms of all other Contract Documents, except the terms of any
Supplemental Conditions shall take precedence over the Construction Agreement and the
General Terms and Conditions. To the extent any conflict in the terms of the Contract
Documents including the Owner's Board approved Executive Summary cannot be resolved by
application of the Supplemental Conditions, if any, or the Construction Agreement and the
General Terms and Conditions, the conflict shall be resolved by imposing the more strict or
costly obligation under the Contract Documents upon the Contractor at Owner's discretion.
30
Construction Services Agreement: Revised 02132017
IN WITNESS WHEREOF, the parties have executed this Agreement on the date(s)
indicated below.
TWO WITNESSES:
CONTRACTOR:
Marine Contracting Group, Inc.
By:
FIRST WITNESS
Print Name and Title Date
Print Name
SECOND WITNESS
Print Name
Date: OWNER:
ATTEST: BOARD OF COUNTY COMMISSIONERS OF
COLLIER COUNTY FLORIDA
Dwight E. Brock, Clerk
BY: BY:
Penny Taylor Date
Chairman
Approved as to Form and Legality:
Assistant County Attorney
Print Name
C,g
31
Construction Services Agreement: Revised 02132017
EXHIBIT A 1: PUBLIC PAYMENT BOND
Cocohatchee River Park Marina Renovations
Bond No.
Contract No. 17-7125
KNOW ALL MEN BY THESE PRESENTS: That
as Principal, and
as Surety,
located at (Business
Address) are held and firmly bound to as Obligee in the
sum of ($ ) for the
payment whereof we bind ourselves, our heirs, executors, personal representatives, successors
and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
2017, with Obligee for in
accordance with drawings and specifications, which contract is
incorporated by reference and made a part hereof, and is referred to herein as the Contract.
THE CONDITION OF THIS BOND is that if Principal
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the Contract, then this bond is void; otherwise it remains
in full force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect Sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.05(2). In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this
Payment Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
2017, the name of each party being affixed and these presents duly signed by
its under -signed representative, pursuant to authority of its governing body.
32
Construction Services Agreement: Revised 02132017
Signed, sealed and delivered
in the presence of:
Witnesses as to Principal
STATE OF _
COUNTY OF
BY:
NAME:
ITS:
PRINCIPAL
The foregoing instrument was acknowledged before me this day of 20
by as of
a corporation, on behalf of the
corporation. He/she is personally known to me OR has produced as
identification and did (did not) take an oath.
My Commission Expires:
NAME:
(AFFIX OFFICIAL SEAL)
ATTEST:
Witnesses to Surety
(Signature of Notary)
(Legibly Printed)
Notary Public, State of
Commission No.:
SURETY:
(Printed Name)
(Business Address
(Authorized Signature)
(Printed Name)
33
Construction Services Agreement: Revised 02132017 qO
ME
As Attorney in Fact
(Attach Power of Attorney)
Witnesses (Printed Name)
(Business Address)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
2017, by , as
of Surety, on
behalf of Surety. He/She is
oath.
My Commission Expires:
(AFFIX OFFICIAL SEAL)
personally known to me OR has produced
as identification and who did (did not) take an
(Signature)
Name:
(Legibly Printed)
Notary Public, State of:
Commission No.:
34
Construction Services Agreement: Revised 02132017
O
KNOW ALL MEN BY THESE PRESENTS: That
as Principal, and
as
Bond No.
Contract No. 17-7125
Surety, located at
(Business Address) are held and firmly bound to
, as Obligee in the sum of
($ ) for the payment whereof we bond ourselves, our heirs, executors,
personal representatives, successors and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
2017, with Obligee for
in
accordance with drawings and specifications, which contract is incorporated by reference and
made a part hereof, and is referred to herein as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Performs the Contract at the times and in the manner prescribed in the Contract; and
2. Pays Obligee any and all losses, damages, costs and attorneys' fees that Obligee
sustains because of any default by Principal under the Contract, including, but not limited to, all
delay damages, whether liquidated or actual, incurred by Obligee; and
3. Performs the guarantee of all work and materials furnished under the Contract for the
time specified in the Contract, then this bond is void; otherwise it remains in full force. Any
changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect Sureties obligation under this Bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of
time, alterations or additions to the terms of the Contract or other work to be performed
hereunder, or the specifications referred to therein shall in anywise affect its obligations under
this bond, and it does hereby waive notice of any such changes, extensions of time, alterations
or additions to the terms of the Contract or to work or to the specifications.
This instrument shall be construed in all respects as a common law bond. It is expressly
understood that the time provisions and statute of limitations under Section 255.05, Florida
Statutes, shall not apply to this bond.
In no event will the Surety be liable in the aggregate to Obligee for more than the penal sum of
this Performance Bond regardless of the number of suits that may be filed by Obligee.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 2017, the name of each party being affixed and these presents duly signed
by its undersigned representative, pursuant to authority of its governing body.
35
Construction Services Agreement: Revised 02132017
Signed, sealed and delivered
in the presence of:
Witnesses as to Principal
STATE OF
COUNTY OF
PRINCIPAL
BY:
NAME:
ITS:
The foregoing instrument was acknowledged before me this day of
2017, by as
of a
corporation, on behalf of the corporation. He/she is personally
known to me OR has produced as
identification and did (did not) take an oath
My Commission Expires:
(AFFIX OFFICIAL SEAL)
(Signature)
Name:
(Legibly Printed)
Notary Public, State of:
Commission No.:
36
Construction Services Agreement: Revised 02132017
9
O
ATTEST:
Witnesses as to Surety
Witnesses
STATE OF
COUNTY OF
SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
(Printed Name)
(Business Address)
(Telephone Number)
The foregoing instrument was acknowledged before me this day of
2017, by as of
,a Surety, on behalf of
Surety. He/She is personally known to me OR has produced
as identification and who did (did not) take an oath.
My Commission Expires:
(AFFIX OFFICIAL SEAL)
(Signature)
Name:
(Legibly Printed)
Notary Public, State of:
Commission No.:
37
Construction Services Agreement: Revised 02132017
EXHIBIT B: INSURANCE REQUIREMENTS
The Vendor shall at its own expense, carry and maintain insurance coverage from responsible companies duly
authorized to do business in the State of Florida as set forth in EXHIBIT B of this solicitation. The Vendor shall
procure and maintain property insurance upon the entire project, if required, to the full insurable value of the
scope of work.
The County and the Vendor waive against each other and the County's separate Vendors, Contractors, Design
Consultant, Subcontractors, agents and employees of each and all of them, all damages covered by property
insurance provided herein, except such rights as they may have to the proceeds of such insurance. The
Vendor and County shall, where appropriab, require similar waivers of subrogation from the County's separate
Vendors, Design Consultants and Subcontractors and shall require each of them to include similar waivers in
their contracts.
Collier County shall be responsible for purchasing and maintaining its own liability insurance.
Certificates issued as a result of the award of this solicitation must identify "For any and all work performed on
behalf of Collier County', or, the specific solicitation number and title.
The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall name Collier
County, Florida, as an additional insured as to the operations of Vendor under this solicitation and shall contain
a severability of interests provisions.
The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of
County Commissioners in Collier County, OR Collier County Government, OR Collier County. The Certificates
of Insurance must state the Contract Number, or Project Number, or specific Project description, or must read:
For any and all work performed on behalf of Collier County.
The amounts and types of insurance coverage shall conform to the minimum requirements set forth in
EXHIBIT B with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If
Vendor has any self-insured retentions or deductibles under any of the below listed minimum required
coverage, Vendor must identify on the Certificate of Insurance the nature and amount of such self- insured
retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All
self-insured retentions or deductibles will be Vendor's sole responsibility.
Coverages shall be maintained without interruption from the date of commencement of the Work until the
date of completion and acceptance of the scope of work by the County or as specified in this solicitation
whichever is longer.
The Vendor and/or its insurance carrier shall provide thirty (30) days written notice to the County of policy
cancellation or non -renewal on the part of the insurance carrier or the Vendor. The Vendor shall also notify the
County, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation,
non -renewal or material change in coverage or limits received by Vendor from its insurer and nothing
contained herein shall relieve Vendor of this requirement to provide notice. In the event of a reduction in the
aggregate limit of any policy to be provided by Vendor hereunder, Vendor shall immediately take steps to have
the aggregate limit reinstated to the full extent permitted under such policy.
Should at any time the Vendor not maintain the insurance coverage(s) required herein, the County may
terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge
the Vendor for such coverages purchased. If Vendor fails to reimburse the County for such costs within thirty
(30) days after demand, the County has the right to offset these costs from any amount due Vendor under this
38
Construction Services Agreement: Revised 02132017
9
O
Agreement or any other agreement between the County and Vendor. The County shall be under no obligation
to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance
company or companies used. The decision of the County to purchase such insurance coverages shall in no
way be construed to be a waiver of any of its rights under the Contract Documents.
If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the scope of
work, the Vendor shall furnish to the County renewal or replacement Certificate(s) of Insurance not later than
ten (10) calendar days after the expiration date on the certificate. Failure of the Vendor to provide the County
with such renewal certificate(s) shall be considered justification for the County to terminate any and all
contracts.
39
Construction Services Agreement: Revised 02132017
Collier County Florida
Insurance and Bonding Requirements
Insurance / Bond Type
Required Limits
1. ® Worker's
Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government
Compensation
Statutory Limits and Requirements
2. ® Employer's Liability
$500,000single limit per occurrence
3. ® Commercial General
Bodily Injury and Property Damage
Liability (Occurrence Form)
patterned after the current
$1,000,000 per occurrence, $2,000,000 aggregate for Bodily Injury Liability
ISO form
and Property Damage Liability. This shall include Premises and Operations;
Independent Contractors; Products and Completed Operations and
Contractual Liability.
4. ® Indemnification
To the maximum extent permitted by Florida law, the ContractorNendor/
Consultant shall indemnify and hold harmless Collier County, its officers and
employees from any and all liabilities, damages, losses and costs, including,
but not limited to, reasonable attorneys' fees and paralegals' fees, to the
extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the ContractorNendor/Consultant or anyone employed or utilized
by the ContractorNendor/Consultant in the performance of this Agreement.
This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an
indemnified party or person described in this paragraph. This section does not
pertain to any incident arising from the sole negligence of Collier County.
4. ® Automobile Liability
$ 1,000,000 Each Occurrence; Bodily Injury & Property Damage, Owned/Non-
owned/Hired; Automobile Included
5. ® Other insurance as
® Watercraft $ 1,000,000= Per Occurrence
noted:
® United States Longshoreman's and Harborworker's Act coverage shall be
maintained where applicable to the completion of the work.
$ 1,000,000 Per Occurrence
® Maritime Coverage (Jones Act) shall be maintained where applicable to
the completion of the work.
$ 1,000,000 Per Occurrence
❑ Aircraft Liability coverage shall be carried in limits of not less than
$5,000,000 each occurrence if applicable to the completion of the Services
under this Agreement.
$ Per Occurrence
❑ Pollution $ Per Occurrence
❑ Professional Liability $ per claim and in
the aggregate
• $1,000,000 per claim and in the aggregate
• $2,000,000 per claim and in the aggregate
❑ Project Professional Liability $ Per Occurrence
40
Construction Services Agreement: Revised 02132017
❑ Valuable Papers Insurance $ Per Occurrence
❑ Employee Dishonesty / Crime $ Per Occurrence
Including Employee Theft, Funds Transfer Fraud, Include a Joint Loss
Payee endorsement naming Collier County.
6. ® Bid bond Shall be submitted with proposal response in the form of certified funds,
cashiers' check or an irrevocable letter of credit, a cash bond posted with the
County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All
checks shall be made payable to the Collier County Board of County
Commissioners on a bank or trust company located in the State of Florida and
insured by the Federal Deposit Insurance Corporation.
7. ® Performance and For projects in excess of $200,000, bonds shall be submitted with the
Payment Bonds executed contract by Proposers receiving award, and written for 100% of the
Contract award amount, the cost borne by the Proposer receiving an award.
The Performance and Payment Bonds shall be underwritten by a surety
authorized to do business in the State of Florida and otherwise acceptable to
Owner; provided, however, the surety shall be rated as "A-" or better as to
general policy holders rating and Class V or higher rating as to financial size
category and the amount required shall not exceed 5% of the reported policy
holders' surplus, all as reported in the most current Best Key Rating Guide,
published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New
York 10038.
8. ® Vendor shall ensure that all subcontractors comply with the same insurance requirements that he is
required to meet. The same Vendor shall provide County with certificates of insurance meeting the required
insurance provisions.
9. ® Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for Commercial
General Liability where required.
10. ® The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board of
County Commissioners in Collier County, OR Collier County Government, OR Collier County. The
Certificates of Insurance must state the Contract Number, or Project Number, or specific Project description,
or must read: For any and all work performed on behalf of Collier County.
11. ® Thirty (30) Days Cancellation Notice required.
Vendor's Insurance Statement
We understand the insurance requirements of these specifications and that the evidence of insurability may be
required within five (5) days of the award of this solicitation.
Name of Firm
Vendor Signature
Print Name
Insurance Agency
Agent Name
Date
Telephone Number
41
Construction Services Agreement: Revised 02132017
EXHIBIT C: RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $ paid,
("Contractor") releases and waives for itself and its subcontractors,
material -men, successors and assigns, all claims demands, damages, costs and expenses, whether in contract or in tort,
against the Board of County Commissioners of Collier County, Florida, relating in any way to the performance of the
Agreement between Contractor and Owner dated 1 2017 for the period from
to excluding all retainage withheld and any pending claims or
disputes as expressly specified as follows:
(2) Contractor certifies for itself and its subcontractors, material -men, successors and assigns, that all charges for
labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a lien or a
demand against any payment bond might be filed, have been fully satisfied and paid.
(3) To the maximum extent permitted by law, Contractor agrees to indemnify, defend and save harmless Owner from
all demands or suits, actions, claims of liens or other charges filed or asserted against the Owner arising out of the
performance by Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment No.
CONTRACTOR
BY:
ITS:
DATE:
Witnesses
STATE OF
COUNTY OF
ident
The foregoing instrument was acknowledged before me this day of 2017, by
as of , a
corporation, on behalf of the corporation. He/she is personally known to me or has produced
as identification and did (did not) take an oath.
My Commission Expires:
(AFFIX OFFICIAL SEAL)
(Signature of Notary)
NAM E:
(Legibly Printed)
Notary Public, State of
Commissioner No.:
42
Construction Services Agreement: Revised 02132017
'i0
EXHIBIT D: FORM OF CONTRACT APPLICATION FOR PAYMENT
Payment, Schedule of Values and Stored Materials Record applications are available for
download at: http://purchasing.colIiergov.net/Forms/Forms/AlIltems.aspx
43
Construction Services Agreement: Revised 02132017
Q
EXHIBIT E: CHANGE ORDER
An electronic data entry form may be found at:
http://bccspO1 /SiteDirectorV/ASD/Purchasing/Forms1 /Forms/DefauIt.aspx
Change Order Form
Contract#: Change#:= 'Purchaseorder4: Prrject :O
Co ntracto 0 R rm Mame: Project Nan*:
Project Manager Mame Department:
Original ContractWork -Order A.meurt
QiginaI BCC Aploraxsl Date; Agenda Item
Current ECC Appr oad Amount
Lsst BCG Approval Gate; Apend�s Item#
Current 1-3ntr-act', ak Order Amount
SAP Contract Expir stir n Date (fatasto
G-olW Amour. t,f this Cham
4Chle'D!
Tots Change from Or ig i na I Amou n t
Rivissdcontract`Wcak Didsr Totsl
S
0,010
?DIV,'0l
Ch.angefromuurrent SCC Approied Arrrunt
Cumula.ti��Chan�
S
0.0n
=d.'°i`10!
Change from CurrsntArmmnt
Completion Date, Description of the Tasks) Change, and Rationale for the Change
Notice PP
Original to Proc Ori inal Last Approved Revised Date
Date Completion Dat Date lt�.ijesttaMWga;
#afDaysAdded 5electTasks ❑ Add newtask{s) 0 Dsletetask(s) ❑ Changetask(s} ❑ Other s4aosaai
Provide a responseto thefeIlowing: 11.) detailed and specific exp Ianationlratioraleof the requestedchange(s:) to theta:sk(s) and 1 or
the ad d iti o nal days added (if requestedi; 2j why this change was not incl uded in the original oo ntra et; and, 3,J describe the impact if
this change is not processed. Altazh sz1,,:9ara€ information from it•e 3_sw prof=_ss> ra; and<or Corlra ford
Prepared by: Llai_:
(Frost Mar3g=_r Name aml D=_parlmert)
Acceplar„_ of :)-i_ C r _ , _ crr _r sha,l cor_1f taa a mcdific atinr m •octad t rrork>nruer 4dertifiex above sra' :uili be sebtsct to all the same
isrmsa 7 _:or aszor?asrsdrn;hGcomrawt:iwork oraeficaicatkabvve,isf.ltyasifihesams were sts, s-1, m I hi -z acceplance. Ttae
a El ms ri. 4 ary' 1n I q Conaractahall constinaeaf�11and firalssitkmeriofany and all ciaimsofthe CoetraclorlVendor consuhart1
D�=,,g r Profssskora i asisingoloforrelatedtothechargesaiforlhhsrein,inclsdiraclaimsforempataanddelaycost.
Accepted by: Dais:
Cortra.I r :rer.dariCorsukams Desi -,r ratssrr,aian3Nameofr•;rm. ipro*cTapplcabie)
Approved by: Daie:
(Design Professi3ralardNarneofFirm ffp..:.-:1.pp -'at-.-=r
Approved by: Dais:
(Frocuremert ?r:Aesaiarai
44
Construction Services Agreement: Revised 02132017
TO
EXHIBIT F: CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
Design Professional's Project No.
This Certificate of Substantial Completion applies to all Work under the Contract Documents or to the
following specified parts thereof:
To
OWNER
And
To
Substantial Completion is the state in the progress of the Work when the Work (or designated
portion) is sufficiently complete in accordance with the Contract Documents so that the Owner
can occupy or utilize the Work for its intended use. The Work to which this Certificate applies has
been inspected by authorized representatives of OWNER, CONTRACTOR AND DESIGN
PROFESSIONAL, and that Work is hereby declared to be substantially complete in accordance with the
requirements of the Contract Documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-inclusive,
and the failure to include an item in it does not alter the responsibility of CONTRACTOR to complete all
the Work in accordance with the Contract Documents. The items in the tentative list shall be completed
or corrected by CONTRACTOR within days of the above date of Substantial Completion.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance,
heat, utilities, insurance and warranties shall be as follows:
45
Construction Services Agreement: Revised 02132017
RESPONSIBILITIES:
OWNER:
CONTRACTOR
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance with the
Contract Documents.
Executed by Design Professional on 20
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on 120
OWNER
By:
Type Name and Title
46
Construction Services Agreement: Revised 02132017
0
EXHIBIT G: FINAL PAYMENT CHECKLIST
Bid No.: Project No.: _
Contractor:
The following items have been secured by the
for the Project known as
Date: 20
and have been reviewed and found to comply with the requirements of the Contract Documents.
Original Contract Amount: Final Contract Amount:
Commencement Date:
Substantial Completion Time as set forth in the Agreement: Calendar Days.
Actual Date of Substantial Completion.-
Final
ompletion:Final Completion Time as set forth in the Agreement: Calendar Days.
Actual Final Completion Date:
YES NO
1. All Punch List items completed on
2. Warranties and Guarantees assigned to Owner (attach to this form).
3. Effective date of General one year warranty from Contractor is:
4. 2 copies of Operation and Maintenance manuals for equipment and
system submitted (list manuals in attachment to this form).
5. As -Built drawings obtained and dated:
6. Owner personnel trained on system and equipment operation.
7. Certificate of Occupancy No.:
issued on (attach to this form).
8. Certificate of Substantial Completion issued on
9. Final Payment Application and Affidavits received from Contractor on:
10. Consent of Surety received on
11. Operating Department personnel notified Project is in operating phase.
12. All Spare Parts or Special Tools provided to Owner:
13. Finished Floor Elevation Certificate provided to Owner:
14. Other:
If any of the above is not applicable, indicate by N/A.
explanation.
Acknowledgments:
By Contractor:
By Design
Professional:
By Owner:
If NO is checked for any of the above, attach
(Company Name)
(Signature)
(Typed Name & Title)
(Firm Name)
(Signature)
(Typed Name & Title)
(Department Name)
(Signature)
(Name & Title)
47
Construction Services Agreement: Revised 02132017
a
0
EXHIBIT H: GENERAL TERMS AND CONDITIONS
1. INTENT OF CONTRACT DOCUMENTS.
1.1 It is the intent of the Contract Documents to describe a functionally complete Project (or
portion thereof) to be constructed in accordance with the Contract Documents. Any work,
materials or equipment that may reasonably be inferred from the Contract Documents as being
required to produce the intended result shall be supplied whether or not specifically called for.
When words which have a well known technical or trade meaning are used to describe work,
materials or equipment, such words shall be interpreted in accordance with that meaning.
Reference to standard specifications, manuals or codes of any technical society, organization or
association or to the laws or regulations of any governmental authority having jurisdiction over
the Project, whether such reference be specific or by implication, shall mean the latest standard
specification, manual, code, law or regulation in effect at the time the Work is performed, except
as may be otherwise specifically stated herein.
1.2 If before or during the performance of the Work Contractor discovers a conflict, error or
discrepancy in the Contract Documents, Contractor immediately shall report same to the Project
Manager in writing and before proceeding with the Work affected thereby shall obtain a written
interpretation or clarification from the Project Manager; said interpretation or clarification from
the Project Manager may require Contractor to consult directly with Design Professional or
some other third party, as directed by Project Manager. Contractor shall take field
measurements and verify field conditions and shall carefully compare such field measurements
and conditions and other information known to Contractor with the Contract Documents before
commencing any portion of the Work.
1.3 Drawings are intended to show general arrangements, design and extent of Work and
are not intended to serve as shop drawings. Specifications are separated into divisions for
convenience of reference only and shall not be interpreted as establishing divisions for the
Work, trades, subcontracts, or extent of any part of the Work. In the event of a discrepancy
between or among the drawings, specifications or other Contract Document provisions,
Contractor shall be required to comply with the provision which is the more restrictive or
stringent requirement upon the Contractor, as determined by the Project Manager. Unless
otherwise specifically mentioned, all anchors, bolts, screws, fittings, fillers, hardware,
accessories, trim and other parts required in connection with any portion of the Work to make a
complete, serviceable, finished and first quality installation shall be furnished and installed as
part of the Work, whether or not called for by the Contract Documents.
2. INVESTIGATION AND UTILITIES.
2.1 Subject to Section 2.3 below, Contractor shall have the sole responsibility of satisfying
itself concerning the nature and location of the Work and the general and local conditions, and
particularly, but without limitation, with respect to the following: those affecting transportation,
access, disposal, handling and storage of materials; availability and quality of labor; water and
electric power; availability and condition of roads; work area; living facilities; climatic conditions
and seasons; physical conditions at the work -site and the project area as a whole; topography
and ground surface conditions; nature and quantity of the surface materials to be encountered;
subsurface conditions; equipment and facilities needed preliminary to and during performance
of the Work; and all other costs associated with such performance. The failure of Contractor to
acquaint itself with any applicable conditions shall not relieve Contractor from any of its
responsibilities to perform under the Contract Documents, nor shall it be considered the basis
for any claim for additional time or compensation.
:o'
48
Construction Services Agreement: Revised 02132017
2.2 Contractor shall locate all existing roadways, railways, drainage facilities and utility
services above, upon, or under the Project site, said roadways, railways, drainage facilities and
utilities being referred to in this Sub -Section 2.2 as the "Utilities". Contractor shall contact the
owners of all Utilities to determine the necessity for relocating or temporarily interrupting any
Utilities during the construction of the Project. Contractor shall schedule and coordinate its
Work around any such relocation or temporary service interruption. Contractor shall be
responsible for properly shoring, supporting and protecting all Utilities at all times during the
course of the Work. The Contractor is responsible for coordinating all other utility work so as to
not interfere with the prosecution of the Work (except those utilities to be coordinated by the
Owner as may be expressly described elsewhere in the Contract Documents).
2.3 Notwithstanding anything in the Contract Documents to the contrary, if conditions are
encountered at the Project site which are (i) subsurface or otherwise concealed physical
conditions which differ materially from those indicated in the Contract Documents or (ii)
unknown physical conditions of an unusual nature, which differ materially from those ordinarily
found to exist and generally recognized as inherent in construction activities of the character
provided for in the Contract Documents, and which reasonably should not have been
discovered by Contractor as part of its scope of site investigative services required pursuant to
the terms of the Contract Documents, then Contractor shall provide Owner with prompt written
notice thereof before conditions are disturbed and in no event later than three (3) calendar days
after first observance of such conditions. Owner and Design Professional shall promptly
investigate such conditions and, if they differ materially and cause an increase or decrease in
Contractor's cost of, or time required for, performance of any part of the Work, Owner will
acknowledge and agree to an equitable adjustment to Contractor's compensation or time for
performance, or both, for such Work. If Owner determines that the conditions at the site are not
materially different from those indicated in the Contract Documents or not of an unusual nature
or should have been discovered by Contractor as part of its investigative services, and that no
change in the terms of the Agreement is justified, Owner shall so notify Contractor in writing,
stating its reasons. Claims by Contractor in opposition to such determination by Owner must be
made within seven (7) calendar days after Contractor's receipt of Owner's written determination
notice. If Owner and Contractor cannot agree on an adjustment to Contractor's cost or time of
performance, the dispute resolution procedure set forth in the Contract Documents shall be
complied with by the parties.
3. SCHEDULE.
3.1 The Contractor, within ten (10) calendar days after receipt of the Notice of Award, shall
prepare and submit to Project Manager, for their review and approval, a progress schedule for
the Project (herein "Progress Schedule"). The Progress Schedule shall relate to all Work
required by the Contract Documents, and shall utilize the Critical Path method of scheduling and
shall provide for expeditious and practicable execution of the Work within the Contract Time.
The Progress Schedule shall indicate the dates for starting and completing the various stages of
the Work.
3.2 The Progress Schedule shall be updated monthly by the Contractor. All monthly
updates to the Progress Schedule shall be subject to the Project Manager's review and
approval. Contractor shall submit the updates to the Progress Schedule with its monthly
Applications for Payment noted below. The Project Manager's review and approval of the
submitted Progress Schedule updates shall be a condition precedent to the Owner's obligation
to pay Contractor.
3.3 All work under this Agreement shall be performed in accordance with the requirements
of all Collier County Noise Ordinances then in effect. Unless otherwise specified, work will
49
Construction Services Agreement: Revised 02132017
generally be limited to the hours of 7:00 a.m. a.m. to 5:00 p.m. p.m., Monday through Friday.
No work shall be performed outside the specified hours without the prior approval of the Project
Manager.
4. PROGRESS PAYMENTS.
4.1 Prior to submitting its first monthly Application for Payment, Contractor shall submit to
Project Manager, for their review and approval, a schedule of values based upon the Contract
Price, listing the major elements of the Work and the dollar value for each element. After its
approval by the Project Manager, this schedule of values shall be used as the basis for the
Contractor's monthly Applications for Payment. This schedule shall be updated and submitted
each month along with a completed copy of the Application for Payment form signed by the
Contractor's authorized representative and attached to the Agreement as Exhibit D.
4.2 Prior to submitting its first monthly Application for Payment, Contractor shall provide to
the Project Manager the list of its Subcontractors and materialmen submitted with its Bid
showing the work and materials involved and the dollar amount of each subcontract and
purchase order. Contractor acknowledges and agrees that any modifications to the list of
Subcontractors submitted with Contractor's Bid and any subsequently identified Subcontractors
are subject to Owner's prior written approval. The first Application for Payment shall be
submitted no earlier than thirty (30) days after the Commencement Date. Notwithstanding
anything herein to the contrary, if approved by Owner in its sole discretion, Contractor may
submit its invoice for any required Payment and Performance Bonds prior to the first Application
of Payment provided that Contractor has furnished Owner certified copies of the receipts
evidencing the premium paid by Contractor for the bonds.
4.3 Unless expressly approved by Owner in advance and in writing, said approval at
Owner's sole discretion, Owner is not required to make any payment for materials or equipment
that have not been incorporated into the Project. If payment is requested on the basis of
materials and equipment not incorporated into the Project, but delivered and suitably stored at
the site or at another location, and such payment and storage have been agreed to by Owner in
writing, the Application for Payment also shall be accompanied by a bill of sale, invoice or other
documentation warranting that the Owner has received the materials and equipment free and
clear of all liens, charges, security interests and encumbrances, together with evidence that the
materials and equipment are covered by appropriate property insurance and other
arrangements to protect Owner's interest therein, all of which shall be subject to the Owner's
satisfaction. Thereafter, with each Application for Payment, Contractor also shall complete and
submit to Owner as part of its Application for Payment, the Stored Materials Record attached
hereto and made a part hereof as Exhibit D.
4.4 Contractor shall submit six (6) copies of its monthly Application for Payment to the
Project Manager or his or her designee, as directed by Owner (which designee may include the
Design Professional). After the date of each Application for Payment is stamped as received
and within the timeframes set forth in Section 218.735 F.S., the Project Manager, or Design
Professional, shall either: (1) Indicate its approval of the requested payment; (2) indicate its
approval of only a portion of the requested payment, stating in writing its reasons therefore; or
(3) return the Application for Payment to the Contractor indicating, in writing, the reason for
refusing to approve payment. Payments of proper invoices in the amounts approved shall be
processed and paid in accordance with Section 218.735, F.S. and the administrative procedures
established by the County's Procurement Services Division and the Clerk of Court's Finance
Department respectively.
50 0
Construction Services Agreement: Revised 02132017
4.5 In the event of a total denial by Owner and return of the Application for Payment by the
Project Manager, the Contractor may make the necessary corrections and re -submit the
Application for Payment. The Owner shall, within ten (10) business days after the Application
for Payment is stamped and received and after Project Manager approval of an Application for
Payment, pay the Contractor the amounts so approved.
4.6 Owner shall retain ten percent (10%) of the gross amount of each monthly payment
request or ten percent (10%) of the portion thereof approved by the Project Manager for
payment, whichever is less. Such sum shall be accumulated and not released to Contractor until
final payment is due unless otherwise agreed to by the Owner in accordance with Florida
Statute 255.078. The Project Manager shall have the discretion to establish, in writing, a
schedule to periodically reduce the percentage of cumulative retainage held throughout the
course of the Project schedule. Owner shall reduce the amount of the retainage withheld on
each payment request subsequent to fifty percent (50%) completion subject to the guidelines
set forth in Florida Statute 255.078 and as set forth in the Owner's procurement ordinance and
policies.
4.7 Monthly payments to Contractor shall in no way imply approval or acceptance of
Contractor's Work.
4.8 Each Application for Payment, subsequent to the first pay application, shall be
accompanied by a Release and Affidavit, in the form attached as Exhibit C, acknowledging
Contractor's receipt of payment in full for all materials, labor, equipment and other bills that are
then due and payable by Owner with respect to the current Application for Payment. Further, to
the extent directed by Owner and in Owner's sole discretion, Contractor shall also submit a
Release and Affidavit from each Subcontractor, sub -subcontractor, or supplier in the form
attached as Exhibit C acknowledging that each Subcontractor, sub -subcontractor or supplier
has been paid in full through the previous month's Application for Payment. The Owner shall not
be required to make payment until and unless these affidavits are furnished by Contractor.
4.9 Contractor agrees and understands that funding limitations exist and that the
expenditure of funds must be spread over the duration of the Project at regular intervals based
on the Contract Amount and Progress Schedule. Accordingly, prior to submitting its first
monthly Application for Payment, Contractor shall prepare and submit for Project Manager's
review and approval, a detailed Project Funding Schedule, which shall be updated as necessary
and approved by Owner to reflect approved adjustments to the Contract Amount and Contract
Time. No voluntary acceleration or early completion of the Work shall modify the time of
payments to Contractor as set forth in the approved Project Funding Schedule.
4.10 Notwithstanding anything in the Contract Documents to the contrary, Contractor
acknowledges and agrees that in the event of a dispute concerning payments for Work
performed under this Agreement, Contractor shall continue to perform the Work required of it
under this Agreement pending resolution of the dispute provided that Owner continues to pay
Contractor all amounts that Owner does not dispute are due and payable.
4.11 Payments will be made for services furnished, delivered, and accepted, upon receipt and
approval of invoices submitted on the date of services or within six (6) months after completion
of contract. Any untimely submission of invoices beyond the specified deadline period is subject
to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be
deemed of the essence with respect to the timely submission of invoices under this agreement.
4.12 The County may, at its discretion, use VISAWASTER card credit network as a payment
vehicle for goods and/or services purchased as a part of this contract. The County may not
51
Construction Services Agreement: Revised 02132017
O
accept any additional surcharges (credit card transaction fees) as a result of using the County's
credit card for transactions relating to this solicitation
5. PAYMENTS WITHHELD.
5.1 The Project Manager may decline to approve any Application for Payment, or portions
thereof, because of subsequently discovered evidence or subsequent inspections that reveal
non-compliance with the Contract Documents. The Project Manager may nullify the whole or
any part of any approval for payment previously issued and Owner may withhold any payments
otherwise due Contractor under this Agreement or any other agreement between Owner and
Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss
because of:
(a) Defective Work not remedied; (b) third party claims filed or reasonable evidence indicating
probable filing of such claims; (c) failure of Contractor to make payment properly to
subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be
completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the
Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work
by the Contractor; or (g) any other material breach of the Contract Documents by Contractor.
5.2 If any conditions described in 5.1. are not remedied or removed, Owner may, after three
(3) days written notice, rectify the same at Contractor's expense. Provided however, in the
event of an emergency, Owner shall not be required to provide Contractor any written notice
prior to rectifying the situation at Contractor's expense. Owner also may offset against any sums
due Contractor the amount of any liquidated or non -liquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other agreement between
Contractor and Owner.
5.3 In instances where the successful contractor may owe debts (including, but not limited to
taxes or other fees) to Collier County and the contractor has not satisfied nor made
arrangement to satisfy these debts, the County reserves the right to off -set the amount owed to
the County by applying the amount owed to the vendor or contractor for services performed of
for materials delivered in association with a contract.
FaUM\111117_VAkTiil41!k11
6.1 Owner shall make final payment to Contractor in accordance with Section 218.735, F.S.
and the administrative procedures established by the County's Procurement Services Division
and the Clerk of Court's Finance Department after the Work is finally inspected and accepted by
Project Manager as set forth with Section 20.1 herein, provided that Contractor first, and as an
explicit condition precedent to the accrual of Contractor's right to final payment, shall have
furnished Owner with a properly executed and notarized copy of the Release and Affidavit
attached as Exhibit C, as well as, a duly executed copy of the Surety's consent to final payment
and such other documentation that may be required by the Contract Documents and the Owner.
Prior to release of final payment and final retainage, the Contractor's Representative and the
Project Manager shall jointly complete the Final Payment Checklist, a representative copy of
which is attached to this Agreement as Exhibit G.
6.2 Contractor's acceptance of final payment shall constitute a full waiver of any and all
claims by Contractor against Owner arising out of this Agreement or otherwise relating to the
Project, except those previously made in writing in accordance with the requirements of the
Contract Documents and identified by Contractor as unsettled in its final Application for
n
52
Construction Services Agreement: Revised 02132017
Payment. Neither the acceptance of the Work nor payment by Owner shall be deemed to be a
waiver of Owner's right to enforce any obligations of Contractor hereunder or to the recovery of
damages for defective Work not discovered by the Design Professional or Project Manager at
the time of final inspection.
SUBMITTALS AND SUBSTITUTIONS.
7.1 Contractor shall carefully examine the Contract Documents for all requirements for
approval of materials to be submitted such as shop drawings, data, test results, schedules and
samples. Contractor shall submit all such materials at its own expense and in such form as
required by the Contract Documents in sufficient time to prevent any delay in the delivery of
such materials and the installation thereof.
7.2 Whenever materials or equipment are specified or described in the Contract Documents
by using the name of a proprietary item or the name of a particular supplier, the naming of the
item is intended to establish the type, function and quality required. Unless the name is
followed by words indicating that no substitution is permitted, materials or equipment of other
suppliers may be accepted by Owner if sufficient information is submitted by Contractor to allow
the Owner to determine that the material or equipment proposed is equivalent or equal to that
named. Requests for review of substitute items of material and equipment will not be accepted
by Owner from anyone other than Contractor and all such requests must be submitted by
Contractor to Project Manager within thirty (30) calendar days after Notice of Award is received
by Contractor, unless otherwise mutually agreed in writing by Owner and Contractor.
7.3 If Contractor wishes to furnish or use a substitute item of material or equipment,
Contractor shall make application to the Project Manager for acceptance thereof, certifying that
the proposed substitute shall adequately perform the functions and achieve the results called for
by the general design, be similar and of equal substance to that specified and be suited to the
same use as that specified. The application shall state that the evaluation and acceptance of
the proposed substitute will not prejudice Contractor's achievement of substantial completion on
time, whether or not acceptance of the substitute for use in the Work will require a change in
any of the Contract Documents (or in the provisions of any other direct contract with Owner for
the Project) to adapt the design to the proposed substitute and whether or not incorporation or
use by the substitute in connection with the Work is subject to payment of any license fee or
royalty. All variations of the proposed substitute from that specified will be identified in the
application and available maintenance, repair and replacement service shall be indicated. The
application also shall contain an itemized estimate of all costs that will result directly or indirectly
from acceptance of such substitute, including costs for redesign and claims of other contractors
affected by the resulting change, all of which shall be considered by the Project Manager in
evaluating the proposed substitute. The Project Manager may require Contractor to furnish at
Contractor's expense additional data about the proposed substitute.
7.4 If a specific means, method, technique, sequence or procedure of construction is
indicated in or required by the Contract Documents, Contractor may furnish or utilize a
substitute means, method, sequence, technique or procedure of construction acceptable to the
Project Manager, if Contractor submits sufficient information to allow the Project Manager to
determine that the substitute proposed is equivalent to that indicated or required by the Contract
Documents. The procedures for submission to and review by the Project Manager shall be the
same as those provided herein for substitute materials and equipment.
7.5 The Project Manager shall be allowed a reasonable time within which to evaluate each
proposed substitute and, if need be, to consult with the Design Professional. No substitute will
be ordered, installed or utilized without the Project Manager's prior written acceptance which
Y
53 C
Construction Services Agreement: Revised 02132017
shall be evidenced by a Change Order, a Work Directive Change, a Field Order or an approved
Shop Drawing. The Owner may require Contractor to furnish at Contractor's expense a special
performance guarantee or other surety with respect to any substitute. The Project Manager will
record time required by the Project Manager and the Project Manager's consultants in
evaluating substitutions proposed by Contractor and making changes in the Contract
Documents occasioned thereby. Whether or not the Owner accepts a proposed substitute,
Contractor shall reimburse Owner for the charges of the Design Professional and the Design
Professional's consultants for evaluating each proposed substitute.
DAILY REPORTS, SIGNED AND SEALED AS-BUILTS AND MEETINGS.
8.1 Unless waived in writing by Owner, Contractor shall complete and submit to Project
Manager on a weekly basis a daily log of the Contractor's work for the preceding week in a
format approved by the Project Manager. The daily log shall document all activities of
Contractor at the Project site including, but not limited to, the following:
8.1.1 Weather conditions showing the high and low temperatures during work
hours, the amount of precipitation received on the Project site, and any other weather conditions
which adversely affect the Work;
8.1.2 Soil conditions which adversely affect the Work;
8.1.3 The hours of operation by Contractor's and Sub -Contractor's personnel;
8.1.4 The number of Contractor's and Sub -Contractor's personnel present and
working at the Project site, by subcontract and trade;
8.1.5 All equipment present at the Project site, description of equipment use and
designation of time equipment was used (specifically indicating any down
time);
8.1.6 Description of Work being performed at the Project site;
8.1.7 Any unusual or special occurrences at the Project site;
8.1.8 Materials received at the Project site;
8.1.9 A list of all visitors to the Project
8.1.10 Any problems that might impact either the cost or quality of the Work or the
time of performance.
The daily log shall not constitute nor take the place of any notice required to be given by
Contractor to Owner pursuant to the Contract Documents.
8.2 Contractor shall maintain in a safe place at the Project site one record copy of the
Contract Documents, including, but not limited to, all drawings, specifications, addenda,
amendments, Change Orders, Work Directive Changes and Field Orders, as well as all written
interpretations and clarifications issued by the Design Professional, in good order and annotated
to show all changes made during construction. The annotated drawings shall be continuously
updated by the Contractor throughout the prosecution of the Work to accurately reflect all field
changes that are made to adapt the Work to field conditions, changes resulting from Change
Orders, Work Directive Changes and Field Orders, and all concealed and buried installations of
54 °
Construction Services Agreement: Revised 02132017
piping, conduit and utility services. All buried and concealed items, both inside and outside the
Project site, shall be accurately located on the annotated drawings as to depth and in
relationship to not less than two (2) permanent features (e.g. interior or exterior wall faces). The
annotated drawings shall be clean and all changes, corrections and dimensions shall be given
in a neat and legible manner in a contrasting color. The "As -Built" record documents, together
with all approved samples and a counterpart of all approved shop drawings shall be available to
the Project Manager or Design Professional for reference. Upon completion of the Work and as
a condition precedent to Contractor's entitlement to final payment, these "As -Built" record
documents, samples and shop drawings shall be delivered to Project Manager by Contractor for
Owner.
8.3 Contractor shall keep all records and supporting documentation, which concern or relate
to the Work hereunder for a minimum of five (5) years from the date of termination of this
Agreement or the date the Project is completed or such longer period as may be required by
law, whichever is later, pursuant to Florida Public Records Law Chapter 119 and comply with
specifically those contractual requirements in 119.0701(2)(a) -(b) as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER
119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC
RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC
RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
The Contractor must specifically comply with the Florida Public Records Law to
1. Keep and maintain public records required by the public agency to perform the
service.
2. Upon request from the public agency's custodian of public records, provide the
public agency with a copy of the requested records or allow the records to be
inspected or copied within a reasonable time at a cost that does not exceed the cost
provided in this chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for
the duration of the contract term and following completion of the contract if the
Contractor does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records
required by the public agency to perform the service. If the Contractor transfers all
public records to the public agency upon completion of the contract, the Contractor
shall destroy any duplicate public records that are exempt or confidential and
exempt from public records disclosure requirements. If the Contractor keeps and
maintains public records upon completion of the contract, the Contractor shall meet
all applicable requirements for retaining public records. All records stored
electronically must be provided to the public agency, upon request from the public
agency's custodian of public records, in a format that is compatible with the
information technology systems of the public agency.
55 a
Construction Services Agreement: Revised 02132017
9. CONTRACT TIME AND TIME EXTENSIONS.
9.1 Contractor shall diligently pursue the completion of the Work and coordinate the Work
being done on the Project by its subcontractors and material -men, as well as coordinating its
Work with all work of others at the Project Site, so that its Work or the work of others shall not
be delayed or impaired by any act or omission by Contractor. Contractor shall be solely
responsible for all construction means, methods, techniques, sequences, and procedures, as
well as coordination of all portions of the Work under the Contract Documents, and the
coordination of Owner's suppliers and contractors as set forth in Paragraph 12.2. herein.
9.2 Should Contractor be obstructed or delayed in the prosecution of or completion of the
Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its
fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of
government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall
notify the Owner in writing within forty-eight (48) hours after the commencement of such delay,
stating the cause or causes thereof, or be deemed to have waived any right which Contractor
may have had to request a time extension.
9.3 No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of its duty to perform or give rise to any
right to damages or additional compensation from Owner. Contractor expressly acknowledges
and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against
Owner will be the right to seek an extension to the Contract Time; provided, however, the
granting of any such time extension shall not be a condition precedent to the aforementioned
"No Damage For Delay" provision. This paragraph shall expressly apply to claims for early
completion, as well as to claims based on late completion.
9.4 In no event shall any approval by Owner authorizing Contractor to continue performing
Work under this Agreement or any payment issued by Owner to Contractor be deemed a waiver
of any right or claim Owner may have against Contractor for delay damages hereunder.
10. CHANGES IN THE WORK.
10.1 Owner shall have the right at any time during the progress of the Work to increase or
decrease the Work. Promptly after being notified of a change, Contractor shall submit an
itemized estimate of any cost or time increases or savings it foresees as a result of the change.
Except in an emergency endangering life or property, or as expressly set forth herein, no
addition or changes to the Work shall be made except upon written order of Owner, and Owner
shall not be liable to the Contractor for any increased compensation without such written order.
No officer, employee or agent of Owner is authorized to direct any extra or changed work orally.
Any alleged changes must be approved by Owner in writing prior to starting such items. Owner
will not be responsible for the costs of any changes commenced without Owner's express prior
written approval. Failure to obtain such prior written approval for any changes will be deemed:
(i) a waiver of any claim by Contractor for such items and (ii) an admission by Contractor that
such items are in fact not a change but rather are part of the Work required of Contractor
hereunder.
10.2 A Change Order, in the form attached as Exhibit E to this Agreement, shall be issued
and executed promptly after an agreement is reached between Contractor and Owner
concerning the requested changes. Contractor shall promptly perform changes authorized by
duly executed Change Orders. The Contract Amount and Contract Time shall be adjusted in
the Change Order in the manner as Owner and Contractor shall mutually agree.
56
}
Construction Services Agreement: Revised 021320177 \�
10.3 If Owner and Contractor are unable to agree on a Change Order for the requested
change, Contractor shall, nevertheless, promptly perform the change as directed by Owner in a
written Work Directive Change. In that event, the Contract Amount and Contract Time shall be
adjusted as directed by Owner. If Contractor disagrees with the Owner's adjustment
determination, Contractor must make a claim pursuant to Section 11 of these General
Conditions or else be deemed to have waived any claim on this matter it might otherwise have
had.
10.4 In the event a requested change results in an increase to the Contract Amount, the
amount of the increase shall be limited to the Contractor's reasonable direct labor and material
costs and reasonable actual equipment costs as a result of the change (including allowance for
labor burden costs) plus a maximum ten percent (10%) markup for all overhead and profit. In
the event such change Work is performed by a Subcontractor, a maximum ten percent (10%)
markup for all overhead and profit for all Subcontractors' and sub -subcontractors' direct labor
and material costs and actual equipment costs shall be permitted, with a maximum five percent
(5%) markup thereon by the Contractor for all of its overhead and profit, for a total maximum
markup of fifteen percent (15%). All compensation due Contractor and any Subcontractor or
sub -subcontractor for field and home office overhead is included in the markups noted above.
Contractor's and Sub -Contractor's bond costs associated with any change order shall be
included in the overhead and profit expenses and shall not be paid as a separate line item. No
markup shall be placed on sales tax, shipping or subcontractor markup.
10.5 Owner shall have the right to conduct an audit of Contractor's books and records to
verify the accuracy of the Contractor's claim with respect to Contractor's costs associated with
any Change Order or Work Directive Change.
10.6 The Project Manager shall have authority to order minor changes in the Work not
involving an adjustment to the Contract Amount or an extension to the Contract Time and not
inconsistent with the intent of the Contract Documents. Such changes may be effected by Field
Order or by other written order. Such changes shall be binding on the Contractor.
10.7 Any modifications to this Contract shall be in compliance with the County procurement
ordinance and policies and Administrative Procedures in effect at the time such modifications
are authorized.
11. CLAIMS AND DISPUTES.
11.1 Claim is a demand or assertion by one of the parties seeking an adjustment or
interpretation of the terms of the Contract Documents, payment of money, extension of time or
other relief with respect to the terms of the Contract Documents. The term "Claim" also includes
other disputes and matters in question between Owner and Contractor arising out of or relating
to the Contract Documents. The responsibility to substantiate a Claim shall rest with the party
making the Claim.
11.2 Claims by the Contractor shall be made in writing to the Project Manager within forty-
eight (48) hours from when the Contractor knew or should have known of the event giving rise
to such Claim or else the Contractor shall be deemed to have waived the Claim. Written
supporting data shall be submitted to the Project Manager within fifteen (15) calendar days after
the occurrence of the event, unless the Owner grants additional time in writing, or else the
Contractor shall be deemed to have waived the Claim. All Claims shall be priced in accordance
with the provisions of Subsection 10.4.
57
Construction Services Agreement: Revised 02132017
11.3 The Contractor shall proceed diligently with its performance as directed by the Owner,
regardless of any pending Claim, action, suit or administrative proceeding, unless otherwise
agreed to by the Owner in writing. Owner shall continue to make payments in accordance with
the Contract Documents during the pendency of any Claim.
12. OTHER WORK.
12.1 Owner may perform other work related to the Project at the site by Owner's own forces,
have other work performed by utility owners or let other direct contracts. If the fact that such
other work is to be performed is not noted in the Contract Documents, written notice thereof will
be given to Contractor prior to starting any such other work. If Contractor believes that such
performance will involve additional expense to Contractor or require additional time, Contractor
shall send written notice of that fact to Owner and Design Professional within forty-eight (48)
hours of being notified of the other work. If the Contractor fails to send the above required forty-
eight (48) hour notice, the Contractor will be deemed to have waived any rights it otherwise may
have had to seek an extension to the Contract Time or adjustment to the Contract Amount.
12.2 Contractor shall afford each utility owner and other contractor who is a party to such a
direct contract (or Owner, if Owner is performing the additional work with Owner's employees)
proper and safe access to the site and a reasonable opportunity for the introduction and storage
of materials and equipment and the execution of such work and shall properly connect and
coordinate its Work with theirs. Contractor shall do all cutting, fitting and patching of the Work
that may be required to make its several parts come together properly and integrate with such
other work. Contractor shall not endanger any work of others by cutting, excavating or
otherwise altering their work and will only cut or alter their work with the written consent of the
Project Manager and the others whose work will be affected. The duties and responsibilities of
Contractor under this paragraph are for the benefit of such utility owners and other Contractors
to the extent that there are comparable provisions for the benefit of Contractor in said direct
contracts between Owner and such utility owners and other contractors.
12.3 If any part of Contractor's Work depends for proper execution or results upon the work of
any other contractor or utility owner (or Owner), Contractor shall inspect and promptly report to
Project Manager in writing any delays, defects or deficiencies in such work that render it
unavailable or unsuitable for such proper execution and results. Contractor's failure to report
will constitute an acceptance of the other work as fit and proper for integration with Contractor's
Work.
13. INDEMNIFICATION AND INSURANCE.
13.1 To the maximum extent permitted by Florida law, Contractor shall defend, indemnify
and hold harmless Owner and its officers and employees from any and all liabilities, claims,
damages, penalties, demands, judgments, actions, proceedings, losses or costs, including, but
not limited to, reasonable attorneys' fees and paralegals' fees, whether resulting from any
claimed breach of this Agreement by Contractor, any statutory or regulatory violations, or from
personal injury, property damage, direct or consequential damages, or economic loss, to the
extent caused by the negligence, recklessness, or intentional wrongful misconduct of
Contractor or anyone employed or utilized by the Contractor in the performance of this
Agreement.
13.2 The duty to defend under this Article 13 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of
a claim by any party and written notice of such claim being provided to Contractor. Contractor's
58
Construction Services Agreement: Revised 02132017 0
obligation to indemnify and defend under this Article 13 will survive the expiration or earlier
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by
the applicable statute of limitations.
13.3 Contractor shall obtain and carry, at all times during its performance under the Contract
Documents, insurance of the types and in the amounts set forth in Exhibit B to the Agreement.
Further, the Contractor shall at all times comply with all of the terms, conditions, requirements
and obligations set forth under Exhibit B.
14. COMPLIANCE WITH LAWS.
14.1 Contractor agrees to comply, at its own expense, with all federal, state and local laws,
codes, statutes, ordinances, rules, regulations and requirements applicable to the Project,
including but not limited to those dealing with taxation, worker's compensation, equal
employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553,
Florida Statutes). If Contractor observes that the Contract Documents are at variance therewith,
it shall promptly notify Project Manager in writing. To the extent any law, rule, regulation, code,
statute, or ordinance requires the inclusion of certain terms in this Agreement in order for this
Agreement to be enforceable, such terms shall be deemed included in this Agreement.
Notwithstanding anything in the Contract Documents to the contrary, it is understood and
agreed that in the event of a change in any applicable laws, ordinances, rules or regulations
subsequent to the date this Agreement was executed that increases the Contractor's time or
cost of performance of the Work, Contractor is entitled to a Change Order for such increases,
except to the extent Contractor knew or should have known of such changes prior to the date of
this Agreement.
14.2 By executing and entering into this agreement, the Contractor is formally acknowledging
without exception or stipulation that it is fully responsible for complying with the provisions of the
Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and
regulations relating thereto, as either may be amended. Failure by the Contractor to comply with
the laws referenced herein shall constitute a breach of this agreement and the County shall
have the discretion to unilaterally terminate this agreement immediately.
14.3 Statutes and executive orders require employers to abide by the immigration laws of the
United States and to employ only individuals who are eligible to work in the United States.
The Employment Eligibility Verification System (E -Verify) operated by the Department of
Homeland Security (DHS) in partnership with the Social Security Administration (SSA), provides
an Internet -based means of verifying employment eligibility of workers in the United States; it is
not a substitute for any other employment eligibility verification requirements. The program will
be used for Collier County formal Invitations to Bid (ITB) and Request for Proposals (RFP)
including professional services and construction services.
Exceptions to the program:
• Commodity based procurement where no services are provided.
• Where the requirement for the affidavit is waived by the Board of County Commissioners
Vendors / Bidders are required to enroll in the E -Verify program, and provide acceptable
evidence of their enrollment, at the time of the submission of the vendor's/bidder's proposal.
Acceptable evidence consists of a copy of the properly completed E -Verify Company Profile
page or a copy of the fully executed E -Verify Memorandum of Understanding for the company.
Vendors are also required to provide the Collier County Procurement Services Division an
59
Construction Services Agreement: Revised 02132017
0
executed affidavit certifying they shall comply with the E -Verify Program. The affidavit is
attached to the solicitation documents. If the Bidder/Vendor does not comply with providing
both the acceptable E -Verify evidence and the executed affidavit the bidder's / vendor's
proposal may be deemed non-responsive.
Additionally, vendors shall require all subcontracted vendors to use the E -Verify system for all
purchases not covered under the "Exceptions to the program" clause above.
For additional information regarding the Employment Eligibility Verification System (E -Verify)
program visit the following website: http://www.dhs.gov/E-Verify. It shall be the vendor's
responsibility to familiarize themselves with all rules and regulations governing this program.
Vendor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall
be fully responsible for complying with the provisions of the Immigration Reform and Control Act
of 1986 as located at 8 U.S.C. 1324, et sea. and regulations relating thereto, as either may be
amended and with the provisions contained within this affidavit. Failure by the awarded firm(s)
to comply with the laws referenced herein or the provisions of this affidavit shall constitute a
breach of the award agreement and the County shall have the discretion to unilaterally
terminate said agreement immediately.
15. CLEANUP AND PROTECTIONS.
15.1 Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste
materials arising out of the Work. At the completion of the Work, Contractor shall remove all
debris, rubbish and waste materials from and about the Project site, as well as all tools,
appliances, construction equipment and machinery and surplus materials, and shall leave the
Project site clean and ready for occupancy by Owner.
15.2 Any existing surface or subsurface improvements, including, but not limited to,
pavements, curbs, sidewalks, pipes, utilities, footings, structures, trees and shrubbery, not
indicated in the Contract Documents to be removed or altered, shall be protected by Contractor
from damage during the prosecution of the Work. Subject to the Section 2.3 above, any such
improvements so damaged shall be restored by Contractor to the condition equal to that existing
at the time of Contractor's commencement of the Work.
16. ASSIGNMENT.
16.1 Contractor shall not assign this Agreement or any part thereof, without the prior consent
in writing of Owner. Any attempt to assign or otherwise transfer this Agreement, or any part
herein, without the Owner's consent, shall be void. If Contractor does, with approval, assign this
Agreement or any part thereof, it shall require that its assignee be bound to it and to assume
toward Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
17. PERMITS, LICENSES AND TAXES.
17.1 Pursuant to Section 218.80, F.S., Owner will pay for all Collier County permits and fees,
including license fees, permit fees, impact fees or inspection fees applicable to the Work
through an internal budget transfer(s). Contractor is not responsible for paying for permits
issued by Collier County, but Contractor is responsible for acquiring all permits. Owner may
require the Contractor to deliver internal budget transfer documents to applicable Collier County
agencies when the Contractor is acquiring permits. Owner will not be obligated to pay for any
permits obtained by Subcontractors.
60
Construction Services Agreement: Revised 02132017 MVP
17.2 All permits, fees and licenses necessary for the prosecution of the Work which are not
issued by Collier County shall be acquired and paid for by the Contractor.
17.3 Contractor shall pay all sales, consumer, use and other similar taxes associated with the
Work or portions thereof, which are applicable during the performance of the Work.
18. TERMINATION FOR DEFAULT.
18.1 Contractor shall be considered in material default of the Agreement and such default
shall be considered cause for Owner to terminate the Agreement, in whole or in part, as further
set forth in this Section, if Contractor: (1) fails to begin the Work under the Contract Documents
within the time specified herein; or (2) fails to properly and timely perform the Work as directed
by the Project Manager or as provided for in the approved Progress Schedule; or (3) performs
the Work unsuitably or neglects or refuses to remove materials or to correct or replace such
Work as may be rejected as unacceptable or unsuitable; or (4) discontinues the prosecution of
the Work; or (5) fails to resume Work which has been suspended within a reasonable time after
being notified to do so; or (6) becomes insolvent or is declared bankrupt, or commits any act of
bankruptcy; or (7) allows anyfinal judgment to stand against it unsatisfied for more than ten (10)
days; or (8) makes an assignment for the benefit of creditors; or (9) fails to obey any applicable
codes, laws, ordinances, rules or regulations with respect to the Work; or (10) materially
breaches any other provision of the Contract Documents.
18.2 Owner shall notify Contractor in writing of Contractor's default(s). If Owner determines
that Contractor has not remedied and cured the default(s) within seven (7) calendar days
following receipt by Contractor of said written notice or such longer period of time as may be
consented to by Owner in writing and in its sole discretion, then Owner, at its option, without
releasing or waiving its rights and remedies against the Contractor's sureties and without
prejudice to any other right or remedy it may be entitled to hereunder or by law, may terminate
Contractor's right to proceed under the Agreement, in whole or in part, and take possession of
all or any portion of the Work and any materials, tools, equipment, and appliances of Contractor,
take assignments of any of Contractor's subcontracts and purchase orders, and complete all or
any portion of Contractor's Work by whatever means, method or agency which Owner, in its
sole discretion, may choose.
18.3 If Owner deems any of the foregoing remedies necessary, Contractor agrees that it shall
not be entitled to receive any further payments hereunder until after the Project is completed.
All moneys expended and all of the costs, losses, damages and extra expenses, including all
management, administrative and other overhead and other direct and indirect expenses
(including Design Professional and attorneys' fees) or damages incurred by Owner incident to
such completion, shall be deducted from the Contract Amount, and if such expenditures exceed
the unpaid balance of the Contract Amount, Contractor agrees to pay promptly to Owner on
demand the full amount of such excess, including costs of collection, attorneys' fees (including
appeals) and interest thereon at the maximum legal rate of interest until paid. If the unpaid
balance of the Contract Amount exceeds all such costs, expenditures and damages incurred by
the Owner to complete the Work, such excess shall be paid to the Contractor. The amount to
be paid to the Contractor or Owner, as the case may be, shall be approved by the Project
Manager, upon application, and this obligation for payment shall survive termination of the
Agreement.
18.4 The liability of Contractor hereunder shall extend to and include the full amount of any
and all sums paid, expenses and losses incurred, damages sustained, and obligations assumed
by Owner in good faith under the belief that such payments or assumptions were necessary or
required, in completing the Work and providing labor, materials, equipment, supplies, and other
61 A
Construction Services Agreement: Revised 02132017 O
items therefore or re -letting the Work, and in settlement, discharge or compromise of any
claims, demands, suits, and judgments pertaining to or arising out of the Work hereunder.
18.5 If, after notice of termination of Contractor's right to proceed pursuant to this Section, it is
determined for any reason that Contractor was not in default, or that its default was excusable,
or that Owner is not entitled to the remedies against Contractor provided herein, then the
termination will be deemed a termination for convenience and Contractor's remedies against
Owner shall be the same as and limited to those afforded Contractor under Section 19 below.
18.6 In the event (i) Owner fails to make any undisputed payment to Contractor within thirty
(30) days after such payment is due or Owner otherwise persistently fails to fulfill some material
obligation owed by Owner to Contractor under this Agreement, and (ii) Owner has failed to cure
such default within fourteen (14) days of receiving written notice of same from Contractor, then
Contractor may stop its performance under this Agreement until such default is cured, after
giving Owner a second fourteen (14) days written notice of Contractor's intention to stop
performance under the Agreement. If the Work is so stopped for a period of one hundred and
twenty (120) consecutive days through no act or fault of the Contractor or its Subcontractors or
their agents or employees or any other persons performing portions of the Work under contract
with the Contractor or any Subcontractor, the Contractor may terminate this Agreement by
giving written notice to Owner of Contractor's intent to terminate this Agreement. If Owner does
not cure its default within fourteen (14) days after receipt of Contractor's written notice,
Contractor may, upon fourteen (14) additional days' written notice to the Owner, terminate the
Agreement and recover from the Owner payment for Work performed through the termination
date, but in no event shall Contractor be entitled to payment for Work not performed or any
other damages from Owner.
19. TERMINATION FOR CONVENIENCE AND RIGHT OF SUSPENSION.
19.1 Owner shall have the right to terminate this Agreement without cause upon seven (7)
calendar days written notice to Contractor. In the event of such termination for convenience,
Contractor's recovery against Owner shall be limited to that portion of the Contract Amount
earned through the date of termination, together with any retainage withheld and reasonable
termination expenses incurred, but Contractor shall not be entitled to any other or further
recovery against Owner, including, but not limited to, damages or any anticipated profit on
portions of the Work not performed.
19.2 Owner shall have the right to suspend all or any portions of the Work upon giving
Contractor not less than two (2) calendar days' prior written notice of such suspension. If all or
any portion of the Work is so suspended, Contractor's sole and exclusive remedy shall be to
seek an extension of time to its schedule in accordance with the procedures set forth in the
Contract Documents. In no event shall the Contractor be entitled to any additional
compensation or damages. Provided, however, if the ordered suspension exceeds six (6)
months, the Contractor shall have the right to terminate the Agreement with respect to that
portion of the Work which is subject to the ordered suspension.
20. COMPLETION.
20.1 When the entire Work (or any portion thereof designated in writing by Owner) is ready
for its intended use, Contractor shall notify Project Manager in writing that the entire Work (or
such designated portion) is substantially complete. Within a reasonable time thereafter, Owner,
Contractor and Design Professional shall make an inspection of the Work (or designated portion
thereof) to determine the status of completion. If Owner, after conferring with the Design
Professional, does not consider the Work (or designated portion) substantially complete, Project
62
Construction Services Agreement: Revised 02132017 O
Manager shall notify Contractor in writing giving the reasons therefore. If Owner, after
conferring with the Design Professional, considers the Work (or designated portion)
substantially complete, Project Manager shall prepare and deliver to Contractor a Certificate of
Substantial Completion which shall fix the date of Substantial Completion for the entire Work (or
designated portion thereof) and include a tentative punch -list of items to be completed or
corrected by Contractor before final payment. Owner shall have the right to exclude Contractor
from the Work and Project site (or designated portion thereof) after the date of Substantial
Completion, but Owner shall allow Contractor reasonable access to complete or correct items
on the tentative punch -list. The Project Manager, shall coordinate with the Contractor the return
of any surplus assets, including materials, supplies, and equipment.
20.2 Upon receipt of written certification by Contractor that the Work is completed in
accordance with the Contract Documents and is ready for final inspection and acceptance,
Project Manager and Design Professional will make such inspection and, if they find the Work
acceptable and fully performed under the Contract Documents shall promptly approve payment,
recommending that, on the basis of their observations and inspections, and the Contractor's
certification that the Work has been completed in accordance with the terms and conditions of
the Contract Documents, that the entire balance found to be due Contractor is due and payable.
Neither the final payment nor the retainage shall become due and payable until Contractor
submits:
(1) Receipt of Contractor's Final Application for Payment.
(2) The Release and Affidavit in the form attached as Exhibit C.
(3) Consent of surety to final payment.
(4) Receipt of the final payment check list.
(5) If required by Owner, other data establishing payment or satisfaction of all
obligations, such as receipts, releases and waivers of liens, arising out of the
Contract Documents, to the extent and in such form as may be designated by
Owner.
Owner reserves the right to inspect the Work and make an independent determination as to the
Work's acceptability, even though the Design Professional may have issued its
recommendations. Unless and until the Owner is completely satisfied, neither the final payment
nor the retainage shall become due and payable.
21. WARRANTY.
21.1 Contractor shall obtain and assign to Owner all express warranties given to Contractor
or any subcontractors by any subcontractor or material men supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents. Contractor further warrants to Owner that all materials and
equipment furnished under the Contract Documents shall be applied, installed, connected,
erected, used, cleaned and conditioned in accordance with the instructions of the applicable
manufacturers, fabricators, suppliers or processors except as otherwise provided for in the
Contract Documents. If, within one (1) year after Substantial Completion, any Work is found to
be defective or not in conformance with the Contract Documents, Contractor shall correct it
promptly after receipt of written notice from Owner. Contractor shall also be responsible for and
pay for replacement or repair of adjacent materials or Work which may be damaged as a result
of such replacement or repair. Further, in the event of an emergency, Owner may commence to
correct any defective Work, without prior notice to Contractor, at Contractor's expense. These
63
Construction Services Agreement: Revised 02132017 0
warranties are in addition to those implied warranties to which Owner is entitled as a matter of
law.
21.2 No later than 30 days prior to expiration of the warranty, the Project Manager, or another
representative of the Owner, shall conduct an inspection of the warranted work to verify
compliance with the requirements of the Agreement. The Contractor's Representative shall be
present at the time of inspection and shall take remedial actions to correct any deficiencies
noted in the inspection. Failure of the Contractor to correct the cited deficiencies shall be
grounds for the Owner to disqualify the Contractor from future bid opportunities with the Owner,
in addition to any other rights and remedies available to Owner.
22. TESTS AND INSPECTIONS.
22.1 Owner, Design Professional, their respective representatives, agents and employees,
and governmental agencies with jurisdiction over the Project shall have access at all times to
the Work, whether the Work is being performed on or off of the Project site, for their
observation, inspection and testing. Contractor shall provide proper, safe conditions for such
access, Contractor shall provide Project Manager with timely notice of readiness of the Work
for all required inspections, tests or approvals.
22.2 If the Contract Documents or any codes, laws, ordinances, rules or regulations of any
public authority having jurisdiction over the Project requires any portion of the Work to be
specifically inspected, tested or approved, Contractor shall assume full responsibility therefore,
pay all costs in connection therewith and furnish Project Manager the required certificates of
inspection, testing or approval. All inspections, tests or approvals shall be performed in a
manner and by organizations acceptable to the Project Manager.
22.3 Contractor is responsible, without reimbursement from Owner, for re -inspection fees and
costs; to the extent such re -inspections are due to the fault or neglect of Contractor.
22.4 If any Work that is to be inspected, tested or approved is covered without written
concurrence from the Project Manager, such work must, if requested by Project Manager, be
uncovered for observation. Such uncovering shall be at Contractor's expense unless Contractor
has given Project Manager timely notice of Contractor's intention to cover the same and Project
Manager has not acted with reasonable promptness to respond to such notice. If any Work is
covered contrary to written directions from Project Manager, such Work must, if requested by
Project Manager, be uncovered for Project Manager's observation and be replaced at
Contractor's sole expense.
22.5 The Owner shall charge to Contractor and may deduct from any payments due
Contractor all engineering and inspection expenses incurred by Owner in connection with any
overtime work. Such overtime work consisting of any work during the construction period
beyond the regular eight (8) hour day and for any work performed on Saturday, Sunday or
holidays.
22.6 Neither observations nor other actions by the Project Manager or Design Professional
nor inspections, tests or approvals by others shall relieve Contractor from Contractor's
obligations to perform the Work in accordance with the Contract Documents.
23. DEFECTIVE WORK.
23.1 Work not conforming to the requirements of the Contract Documents or any warranties
made or assigned by Contractor to Owner shall be deemed defective Work. If required by
64
Construction Services Agreement: Revised 02132017,
Project Manager, Contractor shall as directed, either correct all defective Work, whether or not
fabricated, installed or completed, or if the defective Work has been rejected by Project
Manager, remove it from the site and replace it with non -defective Work. Contractor shall bear
all direct, indirect and consequential costs of such correction or removal (including, but not
limited to fees and charges of engineers, architects, attorneys and other professionals) made
necessary thereby, and shall hold Owner harmless for same.
23.2 If the Project Manager considers it necessary or advisable that covered Work be
observed by Design Professional or inspected or tested by others and such Work is not
otherwise required to be inspected or tested, Contractor, at Project Manager's request, shall
uncover, expose or otherwise make available for observation, inspection or tests as Project
Manager may require, that portion of the Work in question, furnishing all necessary labor,
material and equipment. If it is found that such Work is defective, Contractor shall bear all
direct, indirect and consequential costs of such uncovering, exposure, observation, inspection
and testing and of satisfactory reconstruction (including, but not limited to, fees and charges of
engineers, architects, attorneys and other professionals), and Owner shall be entitled to an
appropriate decrease in the Contract Amount. If, however, such Work is not found to be
defective, Contractor shall be allowed an increase in the Contract Amount and/or an extension
to the Contract Time, directly attributable to such uncovering, exposure, observation, inspection,
testing and reconstruction.
23.3 If any portion of the Work is defective, or if Contractor fails to supply sufficient skilled
workers, suitable materials or equipment or fails to finish or perform the Work in such a way that
the completed Work will conform to the Contract Documents, Project Manager may order
Contractor to stop the Work, or any portion thereof, until the cause for such order has been
eliminated. The right of Project Manager to stop the Work shall be exercised, if at all, solely for
Owner's benefit and nothing herein shall be construed as obligating the Project Manager to
exercise this right for the benefit of Design Engineer, Contractor, or any other person.
23.4 Should the Owner determine, at its sole opinion, it is in the Owner's best interest to
accept defective Work, the Owner may do so. Contractor shall bear all direct, indirect and
consequential costs attributable to the Owner's evaluation of and determination to accept
defective Work. If such determination is rendered prior to final payment, a Change Order shall
be executed evidencing such acceptance of such defective Work, incorporating the necessary
revisions in the Contract Documents and reflecting an appropriate decrease in the Contract
Amount. If the Owner accepts such defective Work after final payment, Contractor shall
promptly pay Owner an appropriate amount to adequately compensate Owner for its
acceptance of the defective Work.
23.5 If Contractor fails, within a reasonable time after the written notice from Project Manager,
to correct defective Work or to remove and replace rejected defective Work as required by
Project Manager or Owner, or if Contractor fails to perform the Work in accordance with the
Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract
Documents, Owner may, after seven (7) days written notice to Contractor, correct and remedy
any such deficiency. Provided, however, Owner shall not be required to give notice to
Contractor in the event of an emergency. To the extent necessary to complete corrective and
remedial action, Owner may exclude Contractor from any or all of the Project site, take
possession of all or any part of the Work, and suspend Contractor's services related thereto,
take possession of Contractor's tools, appliances, construction equipment and machinery at the
Project site and incorporate in the Work all materials and equipment stored at the Project site or
for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow
Owner, Design Professional and their respective representatives, agents, and employees such
65 (Z
Construction Services Agreement: Revised 02132017 O
access to the Project site as may be necessary to enable Owner to exercise the rights and
remedies under this paragraph. All direct, indirect and consequential costs of Owner in
exercising such rights and remedies shall be charged against Contractor, and a Change Order
shall be issued, incorporating the necessary revisions to the Contract Documents, including an
appropriate decrease to the Contract Amount. Such direct, indirect and consequential costs
shall include, but not be limited to, fees and charges of engineers, architects, attorneys and
other professionals, all court costs and all costs of repair and replacement of work of others
destroyed or damaged by correction, removal or replacement of Contractor's defective Work.
Contractor shall not be allowed an extension of the Contract Time because of any delay in
performance of the Work attributable to the exercise by Owner of Owner's rights and remedies
hereunder.
24. SUPERVISION AND SUPERINTENDENTS.
24.1 Contractor shall plan, organize, supervise, schedule, monitor, direct and control the
Work competently and efficiently, devoting such attention thereto and applying such skills and
expertise as may be necessary to perform the Work in accordance with the Contract
Documents. Contractor shall be responsible to see that the finished Work complies accurately
with the Contract Documents. Contractor shall keep on the Work at all times during its progress
a competent resident superintendent, who shall be subject to Owner's approval and not be
replaced without prior written notice to Project Manager except under extraordinary
circumstances. The superintendent shall be employed by the Contractor and be the
Contractor's representative at the Project site and shall have authority to act on behalf of
Contractor. All communications given to the superintendent shall be as binding as if given to
the Contractor. Owner shall have the right to direct Contractor to remove and replaoe its Project
superintendent, with or without cause. Attached to the Agreement as Exhibit N is a list
identifying Contractor's Project Superintendent and all of Contractor's key personnel who are
assigned to the Project; such identified personnel shall not be removed without Owner's prior
written approval, and if so removed must be immediately replaced with a person acceptable to
Owner.
24.2 Contractor shall have a competent superintendent on the project at all times whenever
contractor's work crews, or work crews of other parties authorized by the Project Manager are
engaged in any activity whatsoever associated with the Project. Should the Contractor fail to
comply with the above condition, the Project Manager shall, at his discretion, deduct from the
Contractor's monthly pay estimate, sufficient moneys to account for the Owner's loss of
adequate project supervision, not as a penalty, but as liquidated damages, separate from the
liquidated damages described in Section 5.13, for services not rendered.
25. PROTECTION OF WORK.
25.1 'Contractor shall immediately notify Project Manager and Design Professional. The
Owner or Design Professional shall re-establish the benchmarks and Contractor shall be liable
for all costs incurred by Owner associated therewith.
26. EMERGENCIES.
26.1 In the event of an emergency affecting the safety or protection of persons or the Work or
property at the Project site or adjacent thereto, Contractor, without special instruction or
authorization from Owner or Design Professional is obligated to act to prevent threatened
damage, injury or loss. Contractor shall give Project Manager written notice within forty-eight
(48) hours after Contractor knew or should have known of the occurrence of the emergency, if
A
66 O
Construction Services Agreement: Revised 02132017
Contractor believes that any significant changes in the Work or variations from the Contract
Documents have been caused thereby. If the Project Manager determines that a change in the
Contract Documents is required because of the action taken in response to an emergency, a
Change Order shall be issued to document the consequences of the changes or variations. If
Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
27. USE OF PREMISES.
27.1 Contractor shall maintain all construction equipment, the storage of materials and
equipment and the operations of workers to the Project site and land and areas identified in and
permitted by the Contract Documents and other lands and areas permitted by law, rights of way,
permits and easements, and shall not unreasonably encumber the Project site with construction
equipment or other material or equipment. Contractor shall assume full responsibility for any
damage to any such land or area, or to the owner or occupant thereof, or any land or areas
contiguous thereto, resulting from the performance of the Work.
28. SAFETY.
28.1 Contractor shall be responsible for initiating, maintaining and supervising all safety
precautions and programs in connection with the Work. Contractor shall take all necessary
precautions for the safety of, and shall provide the necessary protection to prevent damage,
injury or loss to:
28.1.1 All employees on or about the project site and other persons and/or
organizations who may be affected thereby;
28.1.2 All the Work and materials and equipment to be incorporated therein,
whether in storage on or off the Project site; and
28.1.3 Other property on Project site or adjacent thereto, including trees, shrubs,
walks, pavements, roadways, structures, utilities and any underground structures or
improvements not designated for removal, relocation or replacement in the Contract
Documents.
28.2 Contractor shall comply with all applicable codes, laws, ordinances, rules and
regulations of any public body having jurisdiction for the safety of persons or property or to
protect them from damage, injury or loss. Contractor shall erect and maintain all necessary
safeguards for such safety and protection. Contractor shall notify owners of adjacent property
and of underground structures and improvements and utility owners when prosecution of the
Work may affect them, and shall cooperate with them in the protection, removal, relocation or
replacement of their property. Contractor's duties and responsibilities for the safety and
protection of the Work shall continue until such time as the Work is completed and final
acceptance of same by Owner has occurred.
All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device
Coordination and Arc Flash Studies where relevant as determined by the engineer.
All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and
PPE Protective labels.
n
67 O
Construction Services Agreement: Revised 02132017
28.3. Contractor shall designate a responsible representative located on a full time basis at
the Project site whose duty shall be the prevention of accidents. This person shall be
Contractor's superintendent unless otherwise designated in writing by Contractor to Owner.
28.4 Alcohol, drugs and all illegal substances are strictly prohibited on any Owner property.
All employees of Contractor, as well as those of all subcontractors and those of any other
person or entity for whom Contractor is legally liable (collectively referred to herein as
"Employees"), shall not possess or be under the influence of any such substances while on any
Owner property. Further, Employees shall not bring on to any Owner property any gun, rifle or
other firearm, or explosives of any kind.
28.5 Contractor acknowledges that the Work may be progressing on a Project site which is
located upon or adjacent to an existing Owner facility. In such event, Contractor shall comply
with the following:
28.5.1 All Owner facilities are smoke free. Smoking is strictly prohibited;
28.5.2 All Employees shall be provided an identification badge by Contractor.
Such identification badge must be prominently displayed on the outside of the Employees'
clothing at all times. All Employees working at the Project site must log in and out with the
Contractor each day;
28.5.3 Contractor shall strictly limit its operations to the designated work areas
and shall not permit any Employees to enter any other portions of Owner's property without
Owner's expressed prior written consent;
28.5.4 All Employees are prohibited from distributing any papers or other
materials upon Owner's property, and are strictly prohibited from using any of Owner's
telephones or other office equipment;
28.5.5 All Employees shall at all times comply with the OSHA regulations with
respect to dress and conduct at the Project site. Further, all Employees shall comply with the
dress, conduct and facility regulations issued by Owner's officials onsite, as said regulations
may be changed from time to time;
28.5.6 All Employees shall enter and leave Owner's facilities only through the
ingress and egress points identified in the site utilization plan approved by Owner or as
otherwise designated, from time to time, by Owner in writing;
28.5.7 When requested, Contractor shall cooperate with any ongoing Owner
investigation involving personal injury, economic loss or damage to Owner's facilities or
personal property therein;
28.5.8 The Employees may not solicit, distribute or sell products while on
Owner's property. Friends, family members or other visitors of the Employees are not permitted
on Owner's property; and
28.5.9 At all times, Contractor shall adhere to Owner's safety and security
regulations, and shall comply with all security requirements at Owner's facilities, as said
regulations and requirements may be modified or changed by Owner from time to time.
68
Construction Services Agreement: Revised 02132017 0
Prior to the commencement of Work, the Contractor shall attend a pre -construction conference
with the Project Manager, Design Professional and others as appropriate to discuss the
Progress Schedule, procedures for handling shop drawings and other submittals, and for
processing Applications for Payment, and to establish a working understanding among the
parties as to the Work. During the prosecution of the Work, the Contractor shall attend any and
all meetings convened by the Project Manager with respect to the Project, when directed to do
so by Project Manager or Design Professional. The Contractor shall have its subcontractors and
suppliers attend all such meetings (including the pre -construction conference) as may be
directed by the Project Manager.
30. VENDOR PERFORMANCE EVALUATION.
Owner has implemented a Vendor Performance Evaluation System for all contracts awarded in
excess of $25,000. To this end, vendors will be evaluated on their performance upon
completion/termination of this Agreement.
31. MAINTENANCE OF TRAFFIC POLICY.
For all projects that are conducted within a Collier County Right -of -Way, the Contractor shall
provide and erect Traffic Control Devices as prescribed in the current edition of the Manual On
Uniform Traffic Control Devices (MUTCD), where applicable on local roadways and as
prescribed in the Florida Department of Transportation's Design Standards (DS), where
applicable on state roadways. These projects shall also comply with Collier County's
Maintenance of Traffic Policy, #5807, incorporated herein by reference. Copies are available
through Risk Management and/or Procurement Services Division, and is available on-line at
colliergov.net/purchasing.
The Contractor will be responsible for obtaining copies of all required manuals, MUTCD, FDOT
Roadway & Traffic Design Standards Indexes, or other related documents, so to become
familiar with their requirements. Strict adherence to the requirements of the Maintenanoe of
Traffic ("MOT") policy will be enforced under this Contract.
All costs associated with the Maintenance of Traffic shall be included on the line item on the bid
page. If MOT is required, MOT is to be provided within ten (10) days of receipt of Notice of
Award.
32. SALES TAX SAVINGS AND DIRECT PURCHASE.
32.1 Contractor shall pay all sales, consumer, use and other similar taxes associated with the
Work or portions thereof, which are applicable during the performance of the Work. No markup
shall be applied to sales tax. Additionally, as directed by Owner and at no additional cost to
Owner, Contractor shall comply with and fully implement the sales tax savings program with
respect to the Work, as set forth in section 32.2 below:
32.2 Notwithstanding anything herein to the contrary, because Owner is exempt from sales
tax and may wish to generate sales tax savings for the Project, Owner reserves the right to
make direct purchases of various construction materials and equipment included in the Work
("Direct Purchase"). Contractor shall prepare purchase orders to vendors selected by
Contractor, for execution by Owner, on forms provided by Owner. Contractor shall allow two
weeks for execution of all such purchase orders by Owner. Contractor represents and warrants
that it will use its best efforts to cooperate with Owner in implementing this sales tax savings
69
Construction Services Agreement: Revised 02132017
program inorder tomaximize cost savings for the Project. Adjustments to the Contract Amount
will be nn8do by appropriate Change Orders for the amounts of each Owner Direct Puroh@Se,
plus the saved sales taxes. A Change Order shall be processed promptly after each Direct
Purchase, or group of similar or ne|@h8d [}inaot Purchnnos, un|aoa otherwise mutually agreed
upon between Owner and Contractor. With respect to all Direct Purchases by C)vvner'
Contractor shall remain responsible for coordinating, 0rder|nQ, inspecting, accepting delivery,
storing, h8nd|ing, inota||ing, warranting and quality control for all Direct Purchases.
Notwithstanding anything herein to the contrary, Contractor expressly acknowledges and agrees
that all [)inant Purchases ahe|| be included within and covered by Contractor's warranty to
Owner tnthe same extent as all other warranties provided by Contractor pursuant to the terms
of the Contract Documents. In the event Owner makes o demand against Contractor with
respect to any Direct Purchase and Contractor wishes to make claim against the manufacturer
or supplier of such Direct PurnhGS8, upon request from Contractor Owner shall oSSiQn to
Contractor any and all warranties and Contract rights Owner may have from any manufacturer
0rsupplier ofany such Direct Purchase byOwner.
32.3 Bidder represents and warrants that it is aware of its statutory responsibilities for sale tax
under Chapter 212, Florida Statutes, and for its responsibilities for Federal excise taxes.
33. SUBCONTRACTS.
53.1 Contractor Sh8|| review the design and Sh8U determine hOvv it desires to divide the
sequence Ofconstruction activities. Contractor will determine the breakdown and composition
of bid packages for award ofsubcontracts, booed on the current Project K8i|eoLune Schedule,
and shall supply o copy of that breakdown and C0nnpVa|tion to Owner and Design Professional
for their review and approval prior to submitting its first Application for Payment. Contractor
shall take into consideration such factors as natural and practical lines of eavensbi|ih/,
sequencing effectiveness, ooceSS and availability constraints, total time for oonnp|ftion.
construction market conditions, availability of labor and materials, COnnnounib/ r8|odono and any
other factors pertinent to Saving time and costs.
38.2 A Subcontractor is any person or entity who is padnrnning, furnishing, supplying Or
providing any portion of the Work pursuant to 8 contract with Contractor. Contractor shall be
solely responsible for and have control over the Subcontractors. Contractor shall negotiate all
Change Drdery, Work Directive Chongeo, Field Orders and Requests for Propoaa|, with all
affected Subcontractors and shall review the oneta of those proposals and advise Owner and
Design Professional oftheir validity and reasonableness, acting inOwner's best interest, prior to
requesting approval of any Change Order from {)vvn8c All Subcontractors performing any
portion of the Work on this Project nnVot be "qualified" as defined in Collier County Ordinance
2013-08. meaning 8 person 0rentity that has the capability in all respects to perform fully the
Agreement requirements with respect to its portion of the Work and hos the integrity and
reliability to assure good faith performance.
33.3 In addition to those Subcontractors identified in Contractor's bid that were approved by
(]vvnar. Contractor also shall identify any other 8uboontnootona, including their nddraaeao.
licensing information and phone numb8ra, it intends to utilize for the Project prior to entering
into any subcontract or purchase order and prior to the Subcontractor commencing any work on
the Project. The list identifying each Subcontractor cannot be modified, changed, or amended
without prior written approval from Owner. Any and all Subcontractor work tObeself-performed
by Contractor must be approved in writing by [}vvnSr in its sole discretion prior to
onnnrnenoennent Of such vvOrh. Contractor shall continuously update that Subcontractor list, SV
that it remains current and accurate throughout the entire performance of the Work.
m
Construction Services Agreement: Revised mu1oco 7
33.4 Contractor shall not enter into a subcontract or purchase order with any Subcontractor, if
Owner reasonably objects to that Subcontractor. Contractor shall not be required to contract
with anyone it reasonably objects to. Contractor shall keep on file a copy of the license for
every Subcontractor and sub -subcontractor performing any portion of the Work, as well as
maintain a log of all such licenses. All subcontracts and purchase orders between Contractor
and its Subcontractors shall be in writing and are subject to Owner's approval. Further, unless
expressly waived in writing by Owner, all subcontracts and purchase orders shall (1) require
each Subcontractor to be bound to Contractor to the same extent Contractor is bound to Owner
by the terms of the Contract Documents, as those terms may apply to the portion of the Work to
be performed by the Subcontractor, (2) provide for the assignment of the subcontract or
purchase order from Contractor to Owner at the election of Owner upon termination of
Contractor, (3) provide that Owner will be an additional indemnified party of the subcontract or
purchase order, (4) provide that Owner, Collier County Government, will be an additional
insured on all liability insurance policies required to be provided by the Subcontractor except
workman's compensation and business automobile policies, (5) assign all warranties directly to
Owner, and (6) identify Owner as an intended third -party beneficiary of the subcontract or
purchase order. Contractor shall make available to each proposed Subcontractor, prior to the
execution of the subcontract, copies of the Contract Documents to which the Subcontractor will
be bound. Each Subcontractor shall similarly make copies of such documents available to its
sub -subcontractors.
33.5 Each Subcontractor performing work at the Project Site must agree to provide field (on-
site) supervision through a named superintendent for each trade (e.g., general concrete forming
and placement, masonry, mechanical, plumbing, electrical and roofing) included in its
subcontract or purchase order. In addition, the Subcontractor shall assign and name a qualified
employee for scheduling direction for its portion of the Work. The supervisory employees of the
Subcontractor (including field superintendent, foreman and schedulers at all levels) must have
been employed in a supervisory (leadership) capacity of substantially equivalent level on a
similar project for at least two years within the last five years. The Subcontractor shall include a
resume of experience for each employee identified by it to supervise and schedule its work.
33.6 Unless otherwise expressly waived by Owner in writing, all subcontracts and purchase
orders shall provide:
33.6.1 That the Subcontractor's exclusive remedy for delays in the performance of
the subcontract or purchase order caused by events beyond its control, including delays
claimed to be caused by Owner or Design Professional or attributable to Owner or Design
Professional and including claims based on breach of contract or negligence, shall be an
extension of its contract time.
33.6.2 In the event of a change in the work, the Subcontractor's claim for
adjustments in the contract sum are limited exclusively to its actual costs for such changes plus
no more than 10% for overhead and profit.
33.6.3 The subcontract or purchase order, as applicable, shall require the
Subcontractor to expressly agree that the foregoing constitute its sole and exclusive remedies
for delays and changes in the Work and thus eliminate any other remedies for claim for increase
in the contract price, damages, losses or additional compensation. Further, Contractor shall
require all Subcontractors to similarly incorporate the terms of this Section 33.6 into their sub -
subcontracts and purchase orders.
33.6.4 Each subcontract and purchase order shall require that any claims by
Subcontractor for delay or additional cost must be submitted to Contractor within the time and in
71
Construction Services Agreement: Revised 02132017 O
the manner in which Contractor must submit such claims to Owner, and that failure to comply
with such conditions for giving notice and submitting claims shall result in the waiver of such
claims.
34.1 Contractor shall maintain at the Project site, originals or copies of, on a current basis, all
Project files and records, including, but not limited to, the following administrative records:
34.1.1
Subcontracts and Purchase Orders
34.1.2
Subcontractor Licenses
34.1.3
Shop Drawing Submittal/Approval Logs
34.1.4
Equipment Purchase/Delivery Logs
34.1.5
Contract Drawings and Specifications with Addenda
34.1.6
Warranties and Guarantees
34.1.7
Cost Accounting Records
34.1.8
Labor Costs
34.1.9
Material Costs
34.1.10
Equipment Costs
34.1.11
Cost Proposal Request
34.1.12
Payment Request Records
34.1.13
Meeting Minutes
34.1.14
Cost -Estimates
34.1.15
Bulletin Quotations
34.1.16
Lab Test Reports
34.1.17
Insurance Certificates and Bonds
34.1.18
Contract Changes
34.1.19
Permits
34.1.20
Material Purchase Delivery Logs
34.1.21
Technical Standards
34.1.22
Design Handbooks
34.1.23
"As -Built" Marked Prints
34.1.24
Operating & Maintenance Instruction
34.1.25
Daily Progress Reports
34.1.26
Monthly Progress Reports
34.1.27
Correspondence Files
34.1.28
Transmittal Records
34.1.29
Inspection Reports
34.1.30
Punch Lists
34.1.31
PMIS Schedule and Updates
34.1.32
Suspense (Tickler) Files of Outstanding
Requirements
The Project files and records shall be available at all times to Owner and Design Professional or
their designees for reference, review or copying.
34.2 Contractor Presentations
At the discretion of the County, the Contractor may be required to provide a brief update on the
Project to the Collier County Board of County Commissioners, "Board", up to two (2) times per
contract term. Presentations shall be made in a properly advertised Public Meeting on a
schedule to be determined by the County Manager or his designee. Prior to the scheduled
presentation date, the Contractor shall meet with appropriate County staff to discuss the
presentation requirements and format. Presentations may include, but not be limited to, the
72
Construction Services Agreement: Revised 02132017
following information: Original contract amount, project schedule, project completion date and
any changes to the aforementioned since Notice to Proceed was issued.
35. SECURITY.
The Contractor is required to comply with County Ordinance 2004-52, as amended. Background
checks are valid for five (5) years and the Contractor shall be responsible for all associated
costs. If required, Contractor shall be responsible for the costs of providing background checks
by the Collier County Facilities Management Division for all employees that shall provide
services to the County under this Agreement. This may include, but not be limited to, checking
federal, state and local law enforcement records, including a state and FBI fingerprint check,
credit reports, education, residence and employment verifications and other related records.
Contractor shall be required to maintain records on each employee and make them available to
the County for at least four (4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check is
valid, as discussed below. All technicians shall have on their shirts the name of the contractor's
business.
The Contractor shall immediately notify the Collier County Facilities Management Division via e-
mail (DL-FMOPS(a)colliergov.net) whenever an employee assigned to Collier County separates
from their employment. This notification is critical to ensure the continued security of Collier
County facilities and systems. Failure to notify within four (4) hours of separation may result in a
deduction of $500 per incident.
CCSO requires separate fingerprinting prior to work being performed in any of their locations.
This will be coordinated upon award of the contract. If there are additional fees for this process,
the vendor is responsible for all costs.
36. VENUE.
Any suit or action brought by either party to this Agreement against the other party relating to or
arising out of this Agreement must be brought in the appropriate federal or state courts in Collier
County, Florida, which courts have sole and exclusive jurisdiction on all such matters.
37. VALUE ENGINEERING.
All projects with an estimated cost of $10 million or more shall be reviewed for consideration of
a Value Engineering (VE) study conducted during project development. A project" shall be
defined as the collective contracts, which may include but not be limited to: design, construction,
and construction, engineering and inspection (CEI) services. Additionally, any project with an
estimated construction value of $2 million or more may be reviewed for VE at the discretion of
the County.
38. ABOVEGROUND/UNDERGROUND TANKS.
38.1 The contractor shall ensure compliance with all NFPA regulations: specifically 110 &
30/30A; FDEP chapter 62 regulations: specifically 761, 762, 777, and 780; 376 & 403 Florida
Statutes; and STI, UL, PEI, ASME, NACE, NLPA, NIST & API referenced standards pertaining
to the storage of hazardous materials and petroleum products.
73
Construction Services Agreement: Revised 02132017 O
38.2 The contractor shall notify the Solid & Hazardous Waste Management Department
(SHWMD) prior to the installation, removal, or maintenance of any storage tank, including day
tanks for generators, storing / will be storing petroleum products or hazardous materials. The
contractor shall provide a 10 day and 48 hour notice to SHWMD 239-252-2508 prior to
commencement.
The contractor shall provide the plans pertaining to the storage tank systems containing
hazardous materials / petroleum products to the SHWMD prior to plans submittal to a permitting
entity and then SHWMD must approve the plans prior to contractor's submittal for permitting.
3. STANDARDS OF CONDUCT: PROJECT A AGE , SUPERVISOR, PL VE S.
The Contractor shall employ people to work on Owner's projects who are neat, clean,
well-groomed and courteous. Subject to the Americans with Disabilities Act, Contractor shall
supply competent employees who are physically capable of performing their employment duties.
The Owner may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Owner's projects
is not in the best interest of the County.
40. DISPUTE RESOLUTION.
Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any such
disputes by negotiation. The negotiation shall be attended by representatives of Contractor with
full decision-making authority and by Owner's staff person who would make the presentation of
any settlement reached during negotiations to Owner for approval. Failing resolution, and prior
to the commencement of depositions in any litigation between the parties arising out of this
Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-
upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by
representatives of Contractor with full decision-making authority and by Owner's staff person or
designee who would make the presentation of any settlement reached at mediation to Owner's
Board for approval. Should either party fail to submit to mediation as required hereunder, the
other party may obtain a court order requiring mediation under Section 44.102, Fla. Stat.
Any suit or action brought by either party to this Agreement against the other party relating to or
arising out of this Agreement must be brought in the appropriate federal or state courts in Collier
County, Florida, which courts have sole and exclusive jurisdiction on all such matters.
74
Construction Services Agreement: Revised 02132017
• I . • • a • . 0 • . • I
75
Construction Services Agreement: Revised 02132017
r -RI,
EXHIBIT J: TECHNICAL SPECIFICATIONS
Supporting documents found at: http://bid.colliergov.net/bid/
and titled: 17-7125 Final Technical Specs
76
Construction Services Agreement: Revised 02132017
0
EXHIBIT K: PERMITS
Supporting documents found at: http://bid.colliergov.net/bid/
and titled: Building PermitlDEP Permit 11-0161644-001,-002,-003 (April 18, 2016)
77
Construction Services Agreement: Revised 02132017 n
��IMIFTIMITM M IMEM
and titled: Proprietary Spec - Cleat/Proprietary Spec - Fenders/Proprietary Spec
Pedestal
78
Construction Services Agreement: Revised 02132017
EXHIBIT M: PLANS AND SPECIFICATIONS
Supporting documents found at: http://bid.colliergov.netibid/
and titled: 17-7125 Final Plans
7s
Construction Services Agreement: Revised 02132017
@0
EXHIBIT N: CONTRACTOR'S KEY PERSONNEL ASSIGNED TO THE PROJECT
Name
Lewis Baker
Jon Blankenbeck
Suzette Baxter
Personnel Category
Construction Superintendent
Project Manager
Project Adminstrator
80
Construction Services Agreement: Revised 02132017