Agenda 06/13/2017 Item #11B06/13/2017
EXECUTIVE SUMMARY
Recommendation to prepare for closeout of the Neighborhood Stabilization Programs (NSP) 1 and
3 by amending the associated Developer Agreements with Habitat for Humanity of Collier County,
Inc. to expend remaining funds in each line of credit resulting from the generation of program
income.
OBJECTIVE: To provide for closeout of the NSP programs.
CONSIDERATIONS: On December 13, 2011, the Board of County Commissioners (BCC) approved an
NSP exit strategy and associated implementation action with the purpose of extricating the County from
daily operations of the Program. The Developer chosen to implement the exit strategy, Habitat for
Humanity, completed NSP3 and has one property remaining for development in the NSP1 that is in the
permitting stages.
The grantor agency, Housing and Urban Development (HUD) provided close out instructions to all
recipients of the NSP funding. The HUD Miami field representative contacted Community and Human
Services (CHS) in April 2017 to begin the closeout process, noting the County had remaining funds in the
lines of credit for both programs to expend. This situation arose because the program activities generated
program income that must be expended and drawn down before funds from the line of credit can be
used/drawn. As part of this exit strategy, CHS, informed the BCC that a plan would be brought back for
consideration in the event program income was generated from the activities associated with the
administration of the program.
HUD advised that the unspent funds are at risk for recapture to the federal treasury at any time, without
notice. However, they did encourage expenditure of these funds if possible. Staff recognizes the need for
additional housing that is affordable in our community and has developed a strategy to move forward to
expend the funds while also mitigating any risk to the County should the funds be recaptured before
expenditure and drawn down from the federal line of credit.
The strategy is to award the remaining funds to the existing Developer, Habitat for Humanity, to acquire
additional properties to rehabilitate and resell them to income-qualified individuals in our community. Via
contract amendment terms, the Developer would accept 100% of the risk associated with a federal fund
recapture before expenditure and drawn down of the funds. In other words, if the funds are swept back to
the treasury at any time before the closing on the purchase of the additional lots, Habitat will agree to
acquire them at that their expense and not seek reimbursement from the County. To further expedite the
recommended acquisitions, the amendments also provide for a wire transfer of funds at the time of
closing, rather than a subsequent reimbursement process that can take 30 - 60 days. HUD allows the
grantee, Collier County, to draw funds from the treasury line of credit no more than three days in advance
of disbursement to the Developer. The use of wire transfer shortens the time frame for the transactions,
and therefore further decreases risk.
All NSP related activities must be performed in accordance with the NSP program guidelines and for the
established eligible uses. The guidelines require the purchase of vacant, abandoned, or foreclosed
properties. The original 2009 eligible census tracts identified in the NSP Admin Plan targeted under
NSP1 and NSP3 will remain as the areas designated as the target areas. Upon recent review, there are
available properties meeting these requirements.
Amendments to each of the Habitat for Humanity agreements are presented for consideration to
implement this recommended closeout strategy. On April 24, 2012 the BCC approved two developer
11.B
Packet Pg. 253
06/13/2017
agreements with Habitat for Humanity for the NSP1 and NSP3 programs, and subsequent amendments
were made to each. Per the terms of the original NSP1 Developer Agreement, Collier County conveyed
thirty-six properties to Habitat to be rehabilitated and sold to income-qualified buyers; this has occurred.
This proposed NSP1 amendment will provide $632,195 to allow for the purchase of two eligible
properties for eligible buyers in the 0-120% AMI range. The original NSP3 Developer agreement
provided funding to purchase, rehabilitate, and resell 30 properties; this has occurred. The proposed NSP3
amendment will provide $215,293 to purchase one eligible property for eligible buyers in the 0-120%
AMI range.
Upon disbursement of the remaining NSP 1 and NSP 3 funds and eligible beneficiaries occupying the
homes, Collier County will be able to request program close out from HUD.
FISCAL IMPACT: Approval of this item will change the funding allocated from the previously
approved agreements. NSP 1 will receive an additional $632,195 and NSP 3 will receive an additional
$215,293. Funds are located in Human Services Grant Fund 121, Project 33050 (NSP1) and Fund 705,
Project 33150 (NSP3).
LEGAL CONSIDERATIONS: This item is approved for form and legality, and requires majority vote
for Board approval. - JAB
GROWTH MANAGEMENT IMPACT: The Neighborhood Stabilization Program facilitates the goals,
objectives, and policies set forth in the Housing Element of the Growth Management Plan.
RECOMMENDATION: To prepare for closeout of the NSP1 and NSP3 by amending the associated
Developer Agreements with Habitat for Humanity of Collier County, Inc.
Prepared By: Tom Calderon, Grants Coordinator, Community and Human Services
ATTACHMENT(S)
1. [Linked] NSP 3 & Prior Amendments (PDF)
2. [Linked] NSP 1 & Prior Amendments (PDF)
3. NSP 3 Final Executed (PDF)
4. NSP 1 Final Executed (PDF)
11.B
Packet Pg. 254
06/13/2017
COLLIER COUNTY
Board of County Commissioners
Item Number: 11.B
Doc ID: 3211
Item Summary: Recommendation to prepare for closeout of the Neighborhood Stabilization
Programs (NSP) 1 and 3 by amending the associated Developer Agreements with Habitat for Humanity of
Collier County Inc. to expend remaining funds in each line of credit resulting from the generation of
program income. (Kim Grant, Community and Human Services Division Director)
Meeting Date: 06/13/2017
Prepared by:
Title: – Community & Human Services
Name: Tomas Calderon
05/15/2017 11:07 AM
Submitted by:
Title: Division Director - Cmnty & Human Svc – Public Services Department
Name: Kimberley Grant
05/15/2017 11:07 AM
Approved By:
Review:
Public Services Department Kimberley Grant Additional Reviewer Completed 05/17/2017 12:11 PM
Public Services Department Joshua Hammond Additional Reviewer Completed 05/22/2017 1:24 PM
Community & Human Services Kristi Sonntag Additional Reviewer Completed 05/22/2017 1:29 PM
Public Services Department Sean Callahan Additional Reviewer Completed 05/22/2017 2:16 PM
Community & Human Services Maggie Lopez Additional Reviewer Completed 05/22/2017 4:03 PM
Public Services Department Hailey Margarita Alonso Level 1 Division Reviewer Completed 05/23/2017 2:49 PM
Grants Erica Robinson Level 2 Grants Review Completed 05/23/2017 3:32 PM
County Attorney's Office Jennifer Belpedio Level 2 Attorney of Record Review Completed 05/24/2017 1:50 PM
Public Services Department Steve Carnell Level 2 Division Administrator Review Completed 05/24/2017 4:28 PM
County Attorney's Office Jeffrey A. Klatzkow Level 3 County Attorney's Office Review Completed 05/25/2017 10:48 AM
Office of Management and Budget Valerie Fleming Level 3 OMB Gatekeeper Review Completed 05/25/2017 10:59 AM
Budget and Management Office Ed Finn Additional Reviewer Completed 05/30/2017 11:13 AM
Grants Therese Stanley Additional Reviewer Completed 06/02/2017 10:27 AM
County Manager's Office Nick Casalanguida Level 4 County Manager Review Completed 06/04/2017 11:26 AM
Board of County Commissioners MaryJo Brock Meeting Pending 06/13/2017 9:00 AM
11.B
Packet Pg. 255
11.B.3
Packet Pg. 256 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 257 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 258 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 259 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 260 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 261 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 262 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 263 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 256 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 257 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 258 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 259 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 260 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 261 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 262 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.3
Packet Pg. 263 Attachment: NSP 3 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 264 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 265 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 266 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 267 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 268 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 269 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 270 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 271 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 272 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 273 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
11.B.4
Packet Pg. 274 Attachment: NSP 1 Final Executed (3211 : NSP 1 and 3 Amendments)
r
NEIGHBORHOOD STABILIZATION PROGRAM 1
CFDA No. 14.218
DEVELOPER AGREEMENT BETWEEN
COLLIER COUNTY
AND
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
(NSP -1)
THIS AGREEMENT, made and entered into on this day of it , 2012, by and between
Collier County, a political subdivision of the State of Florida, hav ng its principal office at 3299
Tamiami Trail East, Naples, Florida 34112 (hereinafter called the "GRANTEE"), and Habitat for
Humanity of Collier County, Inc., a private not-for-profit corporation, existing under the laws of
the State of Florida, having its principal office at 11145 Tamiami Trail East, Naples, Florida
34113 (hereinafter called the "DEVELOPER") to undertake the Neighborhood Stabilization
Program ("NSP -1 ") as approved by the Collier County Board of County Commissioners.
WITNESSETH
WHEREAS, the GRANTEE is the recipient of Neighborhood Stabilization Program
Funds from the U.S. Department of Housing and Urban Development (HUD); and
WHEREAS, the DEVELOPER has submitted a letter of intent, dated December 2, 2011
and incorporated herein by reference, to enter into a partnership with GRANTEE to undertake
an NSP -1 -eligible PROJECT;
NOW, THEREFORE in consideration of the mutual covenants and obligations herein
contained, including the Attachments, and subject to the terms and conditions hereinafter
stated, the parties hereto understand and agree as follows:
I. Definitions
Unless specifically provided otherwise or the context otherwise requires, when used in this
Agreement:
1. "Abandoned" refers to homes or residential properties that either a) mortgage, tribal
leasehold, or tax payments are at least 90 days delinquent, or b) a code
enforcement inspection has determined that the property is not habitable and the
owner has taken no correction actions within 90 days of notification of the
deficiencies, or c) the property is subject to a court-ordered receivership or nuisance
abatement related to abandonment pursuant to state or local law or otherwise meets
a state definition of an abandoned home or residential property.
2. "Appraisal" means an appraisal which meets the criteria specified in the Uniform
Relocation Assistance and Real Property Acquisition Policies Act ("URA"), as further
defined in 49 CFR 24.103.
3. 'Blighted structure" means a structure that exhibits objectively determinable signs of
deteripration sufficient to constitute a threat to human health, safety, and public
welfare as more particularly described in Section 163.340(8), Florida Statutes.
Page 1 of 41
4. "CDBG Act" means the Housing and Community Development Act of 1974, Pub. L.
No. 93-383, as amended. Unless otherwise noted in the Housing and Economic
Recovery Act ("HERA"), as amended, and the alternative requirements in the NSP
Notices, NSP -1 is governed by the CDBG regulations.
5. "Current market appraised value" means the value of a property that is established
through an appraisal made in conformity with either: 1) the appraisal requirement of
the URA at 49 CFR 24.103, or 2) the Uniform Standards of Professional Appraisal
Practice ("USPAP"), or 3) the appraisal requirements of the Federal Housing
Administration ("FHA") or a government sponsored enterprise ("GSE"); and the
appraisal must be completed or updated within 60 days of a final offer made for the
property by a grantee, subrecipient, developer, or individual buyer. However, if the
anticipated value of the proposed acquisition is estimated at $25,000 or less, the
current market appraised value of the property may be established by a valuation of
the property that is based on a review of available data and is made by a person the
grantee determines is qualified to make the valuation.
6. "Eligible Costs" means costs for the activities specified in Exhibit A of this
Agreement for which NSP -1 funds are budgeted, provided that such costs (i) are
incurred in connection with any activity which is eligible under HERA and Section
105A of Title I of the CDBG Act, and (ii) conform to all NSP -1 requirements.
7. "Environmental Requirements" means the requirements described in 24 CFR Part
58.
8. "Foreclosed" refers to a home or residential property if any of the following
conditions apply: (a) the property's current delinquency status is at least 60 days
delinquent under the Mortgage Bankers of America delinquency calculation and the
owner has been notified; (b) the property owner is 90 days or more delinquent on
tax payments; (c) under state, local, or tribal law, foreclosure proceedings have
been initiated or completed; or (d) foreclosure proceedings have been completed
and title has been transferred to an intermediary aggregator or servicer that is not
an NSP -1 grantee, contractor, subrecipient, developer, or end user.
9. "HERA" means the Neighborhood Stabilization Program ("NSP -1") found in Title III
of Division B of the Housing and Economic Recovery Act of 2008, as amended.
10. "HUD" means the United States Department of Housing and Urban Development.
11. "Land bank" means a governmental or nongovernmental nonprofit entity
established, at least in part, to assemble, temporarily manage, and dispose of
vacant land for the purpose of stabilizing neighborhoods and encouraging re -use or
redevelopment of urban property. For the purposes of the NSP -1, a land bank will
operate in a specific, defined geographic area. It will purchase properties that have
been abandoned or foreclosed upon and maintain, assemble, facilitate
redevelopment of, market, and dispose of the land -banked properties. If the land
bank is a governmental entity, it may also maintain abandoned or foreclosed
property that it does not own, provided it charges the owner of the property the full
cost of the service or places a lien on the property for the full cost of the service.
12. "LMMI" is a HUD -defined term incorporating households with eligible incomes (at or
below 120% of area median, based on household size and county), including low-,
moderate-, and middle-income, in referring to the national objective of the CDBG
program.
13. "Low -Income Set -Aside" refers to the HERA requirement that not less than 25
percent of the funds NSP -1 funds to the GRANTEE shall be used for the purchase
and redevelopment of abandoned or foreclosed upon homes or residential
properties that will provide permanent housing to individuals or families whose
incomes do not exceed 50 percent of area median income.
Page 2 of 41
14. "NSP Notice" refers to the alternative requirements for NSP -1 issued by HUD in the
Federal Register on October 6, 2008, as modified in the Bridge Notice issued on
June 19, 2009, and the Unified Notice issued on October 19, 2010.
15. "NSP -1 Funds" mean those funds to be provided by the GRANTEE pursuant to the
terms of this Agreement, as specified in Section II of this Agreement.
16. "Program Income" means the NSP -1 portion of any proceeds received by the
DEVELOPER and repaid to the GRANTEE.
17. "PROJECT" means the activities described in Exhibit A of this Agreement which are
to be carried out to meet the objectives of the NSP -1.
18. "Purchase Discount" means the minimum discount percentage from the current
market- appraised value under which a property may be purchased. Under HUD
Notice FR -5255—N-02, the purchase discount for NSP -1 is "at least 1 percent from
the current market -appraised value of the home or property."
19. "Vacant properties" includes both vacant land and properties with vacant structures
on the land.
11. Terms and Conditions of the Funding
A. Funding Amount — NSP -1 Funds in the amount of Two Hundred Thirty One Thousand and
001100 Dollars ($231,000) are obligated for use in compliance with this agreement, as
reflected in the budget in Exhibit B.
1. These amounts represent an allocation of the GRANTEE's NSP -1 funding
contingent upon DEVELOPER performance and not an entitlement to a certain
grant amount, and shall only be disbursed for approved costs.
2. Approved budget — The approved budget is attached to this agreement as Exhibit B.
It is understood and agreed that funds will be used according to the approved
budget.
3. Activity Limitations — In implementing projects, DEVELOPER shall undertake only
those activities permitted by this agreement, and comply with all provisions of this
agreement, including the project requirements in Section III, as they may be
modified by HUD.
B. Cost Limits — All uses of NSP funds are subject to the approval of the GRANTEE.
1. Cost Limits on Individual Properties — The cost and assistance limits checked below
apply to every property assisted with NSP -1 funds under this agreement, unless
otherwise approved by GRANTEE.
® Developer fee allowed per property $5,500
C. Sale to Buyers — All properties under this agreement, unless such property will serve an
non -development use as described in Exhibit A, shall be sold to eligible buyers in
accordance with the provisions of this section.
1. Eligible Buyers — Eligible homebuyers must be determined to be income -eligible in
compliance with incomes not exceeding 120% area median income.
2. Sales Price — Sales prices must be in compliance with the price limits in Section
III.E, and the sales price of each property must be approved by GRANTEE.
3. Income Certification and Documentation — Every purchaser shall be determined to
be eligible according to the requirements at 24 CFR 570.5.
Page 3 of 41
4. Net Proceeds of Sale — Upon sale of an NSP -1 -funded home, DEVELOPER will
retain all net proceeds for future use as approved by GRANTEE. Such future use
must be for an NSP -eligible activity. GRANTEE has explicitly elected to forgo
recapture of any and all net proceeds and to have such net proceeds remain with
DEVELOPER.
III. Project Requirements
The DEVELOPER agrees to comply with all requirements of the NSP -1 as stated in the NSP
Notice and CDBG regulations, including but not limited to the following:
A. NSP -1 Eligible Use, CDBG National Objective and Eligible Activities — The DEVELOPER
will ensure and document that its NSP -1 activities meet LMMI national objective, eligible
use, allowable cost, and eligible activity requirements of the NSP Notices and CDBG
Regulations.
1. Occupied properties — If the PROJECT is occupied at the time of this commitment,
the DEVELOPER will comply with the relocation requirements of 24 CFR 570.606.
B. Construction/rehabilitation — For any construction or rehabilitation in this project,
DEVELOPER will comply with the provisions of Section VI. If this project involves the
construction or rehabilitation of properties with 8 or more units, the DEVELOPER shall
comply with the provisions of the Davis -Bacon Act and regulations (29 CFR, Part 5), as
amended. If the building or commonly owned development (e.g. condo or townhouse)
has 8 or more units, Davis Bacon is applicable, even if NSP -1 funds only treat one unit.
C. Demolition - Primary structures on properties contributed to DEVELOPER may not be
demolished unless they are declared as blighted by GRANTEE. Such declarations by
GRANTEE shall be made in conformance with the definition contained in Section
163.340(8), Florida Statutes.
D. Property Standards — The DEVELOPER will carry out all NSP -1 -assisted activities in
accordance with applicable laws, codes, and other requirements relating to housing
safety, quality, and habitability, in order to sell, rent, or redevelop such homes and
properties.
1. Rehabilitation Standards — DEVELOPER will carry out all NSP -1 -assisted
rehabilitation of a foreclosed -upon home or residential property in compliance with
the rehabilitation standards in the GRANTEE's NSP -1 substantial amendment, and
in accordance with applicable laws, codes, and other requirements relating to
housing safety, quality, and habitability.
2. Lead-based paint — The DEVELOPER agrees that any construction or rehabilitation
of residential structures with assistance provided under this Agreement shall be
subject to HUD Lead -Based Paint Regulations at 24 CFR 570.487 or 24 CFR
570.608, and 24 CFR Part 35, Subpart B. Such regulations pertain to all NSP -1 -
assisted housing and require that all owners, prospective owners, and tenants of
properties constructed prior to 1978 be properly notified that such properties may
include lead-based paint. Such notification shall point out the hazards of lead-
based paint and explain the symptoms, treatment and precautions that should be
taken when dealing with lead-based paint poisoning and the advisability and
availability of blood lead level screening for children under seven. The notice
should also point out that if lead-based paint is found on the property, abatement
measures may be undertaken. The regulations further require that, depending on
Page 4 of 41
the amount of Federal funds applied to a property, paint testing, risk assessment,
treatment and/or abatement may be conducted.
3. Accessibility — The DEVELOPER shall work with any homebuying household that
includes a person with disabilities to provide accessibility modifications required
under the policy of reasonable accommodations and reasonable modifications. All
such modifications shall be considered to be eligible NSP -1 costs under this
Agreement.
E. Maximum Sales Price — The final sales price shall not exceed the amount permitted by the
NSP -1 requirements listed below:
1. If an abandoned or foreclosed upon home or residential property is to be sold to an
Individual as a primary residence, no profit may be earned on such sale.
2. HERA Section 2301(d)(2) directs that the sale of such property shall be in an
amount equal to or less than the cost to acquire and redevelop or rehabilitate such
home or property up to a decent, safe, and habitable condition. Further, the sale
price must be the lesser of the post -development fair market value or the
acquisition/redevelopment cost.
3. The maximum sales price for a property is determined by aggregating all costs of
acquisition, rehabilitation, and redevelopment (including related activity delivery
costs, which generally include, among other things, costs related to the sale of
property).
4. In determining the sales price, the GRANTEE will NOT consider the costs of
boarding up, lawn mowing, maintaining the property in a static condition, or, in the
absence of NSP -1 -assisted rehabilitation or redevelopment, the costs of completing
a sales transaction or other disposition to be redevelopment or rehabilitation costs.
F. Sale and Occupancy — All of the properties made available under this Agreement shall be
used with respect to:
1. Buyer Qualification — All buyers of NSP -1 -assisted units shall be individuals and
families whose incomes do not exceed 120% of area median income (referred to as
"low-, moderate- and middle-income", or LMMI). DEVELOPER shall verify and
document income eligibility of all buyers in compliance with 570.203(a) definition of
"Income."
a. Low -Income Set -Aside (if applicable) — If applicable, the DEVELOPER must
expend at least the amount of set-aside funding identified in Exhibit A of this
Agreement to create permanent housing for households with incomes at or
below 50% of area median. The DEVELOPER may choose to expend more
than the set-aside amount from NSP -1 funds allocated within Eligible Uses A
and B, but within the total NSP -1 award covered by this agreement, and doing
so will not require an amendment to this Agreement.
2. Counseling Requirement— Each NSP -1 -assisted homebuyer is required to complete
at least eight hours of homebuyer counseling from a HUD -approved housing
counseling agency or a counselor approved by the GRANTEE.
3. First Mortgage — DEVELOPER must ensure that homebuyers obtain a mortgage
loan from a lender who agrees to comply with the bank regulators' guidance for non-
traditional mortgages. DEVELOPER is prohibited from permitting homebuyers to
obtain subprime mortgages for whom such mortgages are inappropriate.
4. Affordability Period — All NSP -1 -assisted units must adhere to the affordability
Page 5 of 41
provisions as listed in Exhibit A-2, which is based upon the total amount of NSP -1
funds provided per unit.
a. Affordability periods must be enforced utilizing a mortgage, promissory note
and, where applicable, deed restriction.
b. The Affordability Period is a minimum standard, and DEVELOPER may
propose a longer Affordability Period.
G. Project Monitoring and Recordkeeping — The DEVELOPER will be monitored by the
GRANTEE for compliance with the NSP -1 requirements and the applicable CDBG
regulations of 24 CFR Part 570. The DEVELOPER will provide reports and access to
project files, including homebuyer files, as requested by the GRANTEE during the
PROJECT and for five (5) years after completion and closeout of the AGREEMENT as
required under Section VIII of this Agreement.
IV. GRANTEE Responsibilities
A. GRANTEE is responsible for the following tasks and deliverables.
B. The GRANTEE shall furnish the DEVELOPER with information regarding requirements for
the project, including any changes in NSP -1 regulations or program limits that affect the
project, including but not limited to income limits.
C. Environmental Review — GRANTEE will complete environmental assessments and provide
clearances for all NSP -1 target areas, as well as approvals of site-specific environmental
reviews. DEVELOPER will provide all information required by GRANTEE.
D. Inspections — The GRANTEE will conduct progress inspections of work completed and
review of project files and information to protect its interests and regulatory authority for
the project, and will provide information to the DEVELOPER regarding any progress
inspections or monitoring to assist it in ensuring compliance. The GRANTEE's review
and approval will relate only to overall compliance with the general requirements of this
Agreement and NSP -1 requirements, and all GRANTEE regulations and ordinances.
E. Reporting — GRANTEE will report to HUD via the Disaster Recovery Grant Reporting
System (DRGR) system and on www.FederalReporting.gov in a timely manner as required
by HUD.
F. Monitoring — GRANTEE will monitor all program activities of DEVELOPER to assure
compliance with the terms of this Agreement including all NSP -1 requirements.
G. Nothing contained herein shall relieve the DEVELOPER of any responsibility as provided
under this Agreement.
V. Disbursement of Funds
A. Requests for payment of developer fees must be submitted by the DEVELOPER on forms
specified by the GRANTEE, with adequate and proper documentation. The DEVELOPER
agrees to submit requests for payment in a timely manner in the form and times directed
by the GRANTEE.
B. The GRANTEE will pay to the DEVELOPER funds available under this Agreement based
upon information submitted by the DEVELOPER and consistent with any approved budget
and GRANTEE policy concerning payments.
Page 6 of 41
C. The GRANTEE reserves the right to inspect records and project sites to determine that
compensation requests are reasonable. The GRANTEE also reserves the right to hold
payment until adequate documentation has been provided and reviewed.
D. The GRANTEE shall pay the DEVELOPER as maximum compensation for the developer
services as provided in the approved Budget in Exhibit B. If multiple projects or buildings
are involved, the developer fee may be pro -rated to each building or project, and the
applicable percentage may be applied to each.
VI. Contracting, Labor & Hiring Provisions
During the performance of this contract, the DEVELOPER agrees as follows:
A. The DEVELOPER will not discriminate against any employee or applicant for employment
because of race, color, religion, sex, or national origin(s). The DEVELOPER will take
affirmative action to ensure the applicants are employed, and that employees are treated
during employment, without regard to their race, color, religion, sex or national origins).
Such action shall include, but not be limited to, the following: employment, upgrading,
demotion, or transfer, recruitment or recruitment advertising; layoff or termination; rates of
pay or other forms of compensation; and selection for training, including apprenticeship.
The DEVELOPER agrees to post in conspicuous places, available to employees and
applicants for employment, notices to be provided by the contracting officer of the
GRANTEE setting forth the provisions of this nondiscrimination clause.
B. The DEVELOPER will, in all solicitations or advertisements for employees placed by or on
behalf of the DEVELOPER, state that all qualified applicants will receive consideration for
employment without regard to race, color, religion, sex, or national origin.
C. The DEVELOPER will comply with all provisions of Executive Order 11246 of September
24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor.
D. The DEVELOPER will furnish all information and reports required by Executive Order
11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary
of Labor, or pursuant thereto, and will permit access to its books, records, and accounts
by the GRANTEE and the Secretary of Labor for purposes of investigation to ascertain
compliance with such rules, regulations, and order.
In the event the DEVELOPER is found to be in noncompliance with the
nondiscrimination clauses of this contract or with any of such rules, regulations or
orders, this contract may be canceled, terminated or suspended in whole or in part
and the DEVELOPER may be declared ineligible for further Government contracts
in accordance with procedures authorized in Executive Order 11246 of September
24, 1965, and such other sanctions may be imposed and remedies invoked as
provided in Executive Order 11246 of September 24, 1965 or by rule, regulations, or
order of the Secretary of Labor or as otherwise provided by law.
E. The DEVELOPER will include the provisions of this Section in every subcontract or
purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor
issued pursuant to Section 204 of Executive Order 11246 of September 24, 1965, so that
such provisions will be binding upon each subcontractor or vendor. The DEVELOPER will
take such action with respect to any subcontract or purchase order as the GRANTEE may
direct as a means of enforcing such provisions, including sanctions for noncompliance;
Page 7 of 41
provided, however, that in the event the DEVELOPER becomes involved in, or is
threatened with litigation with a subcontractor or vendor as a result of such direction by
the GRANTEE, the DEVELOPER may request the United States to enter into such
litigation to protect the interest of the United States.
F. The DEVELOPER agrees to comply with the non-discrimination in employment and
contracting opportunities laws, regulations, and executive orders referenced in 24 CFR
570.607, as revised by Executive Order 13279. The applicable non-discrimination
provisions in Section 109 of the HCDA are still applicable.
G. The DEVELOPER agrees to comply with the requirements of the Secretary of Labor in
accordance with the Davis -Bacon Act, as amended, the provisions of Contract Work
Hours and Safety Standards Act (40 U.S.C. 327 et seq.) and all other applicable Federal,
state and local laws and regulations pertaining to labor standards insofar as those acts
apply to the performance of this Agreement.
H. The DEVELOPER agrees to comply with the Copeland Anti -Kick Back Act (18 U.S.C. 874
et seq.) and its implementing regulations of the U.S. Department of Labor at 29 CFR Part
5. The DEVELOPER shall maintain documentation that demonstrates compliance with
hour and wage requirements of this part. Such documentation shall be made available to
the GRANTEE for review upon request.
I. The DEVELOPER will use its best efforts to afford small businesses, minority business
enterprises, and women's business enterprises the maximum practicable opportunity to
participate in the performance of this contract. As used in this contract, the terms "small
business" means a business that meets the criteria set forth in Section 3(a) of the Small
Business Act, as amended (15 U.S.C. 632), and "minority and women's business
enterprise" means a business at least fifty-one (51) percent owned and controlled by
minority group developers or women. The DEVELOPER may rely on written
representations by businesses regarding their status as minority and women -owned
business enterprises in lieu of an independent investigation.
J. The DEVELOPER agrees that, except with respect to the rehabilitation or construction of
residential property containing less than eight (8) units, all contractors engaged under
contracts in excess of $2,000.00 for construction, renovation or repair work financed in
whole or in part with assistance provided under this contract, shall comply with Federal
requirements adopted by the GRANTEE pertaining to such contracts and with the
applicable requirements of the regulations of the Department of Labor, under 29 CFR
Parts 1, 3, 5 and 7 governing the payment of wages and ratio of apprentices and trainees
to journey workers; provided that, if wage rates higher than those required under the
regulations are imposed by state or local law, nothing hereunder is intended to relieve the
DEVELOPER of its obligation, if any, to require payment of the higher wage. The
DEVELOPER shall cause or require to be inserted in full, in all such contracts subject to
such regulations, provisions meeting the requirements of this paragraph. The
DEVELOPER shall comply with the provisions of the Copeland Anti -Kick -Back Act (18
U.S.C. 874) as supplemented in Labor Regulations (29 CFR Part 3), as amended.
K. Compliance with the provisions of Section 3 of the Housing and Urban Development Act
of 1968, as amended, and as implemented by the regulations set forth in 24 CFR 135,
and all applicable rules and orders issued hereunder prior to the execution of this contract,
shall be a condition of the Federal financial assistance provided under this contract and
binding upon the GRANTEE, the DEVELOPER and any of the DEVELOPER's contractors
Page 8 of 41
and subcontractors. The DEVELOPER certifies and agrees that no contractual or other
disability exists that would prevent compliance with these requirements.
1. The DEVELOPER further agrees to comply with these Section 3 requirements and
to include the following language in all subcontracts executed under this Agreement;
"The work to be performed under this Agreement is a project assisted under a
program providing direct Federal financial assistance from HUD and is subject to the
requirements of Section 3 of the Housing and Urban Development Act of 1968, as
amended (12 U.S.C. 1701). Section 3 requires that to the greatest extent feasible
opportunities for training and employment be given to low- and very low-income
residents of the project area, and that contracts for work in connection with the
project be awarded to business concerns that provide economic opportunities for
low- and very low-income persons residing in the metropolitan area in which the
project is located."
2. The DEVELOPER further agrees to ensure that opportunities for training and
employment arising in connection with a housing rehabilitation (including reduction
and abatement of lead-based paint hazards), housing construction, or other public
construction project are given to low- and very low-income persons residing within
the metropolitan area in which the NSP -1 -funded project is located; where feasible,
priority should be given to low- and very low-income persons within the service area
of the project or the neighborhood in which the project is located, and to low- and
very low-income participants In other HUD programs; and award contracts for work
undertaken in connection with a housing rehabilitation (including reduction and
abatement of lead-based paint hazards), housing construction, or other public
construction project to business concerns that provide economic opportunities for
low- and very low-income persons residing within the metropolitan area in which the
NSP -1 -funded project is located; where feasible, priority should be given to business
concerns that provide economic opportunities to low- and very low-income residents
within the service area or the neighborhood in which the project is located, and to
low- and very low-income participants in other HUD programs.
3. The DEVELOPER further warrants and agrees to include or cause to be included
the criteria and requirements of this Section in every non-exempt subcontract in
excess of $100,000. The DEVELOPER also agrees to take such action as the
federal, state or local government may direct to enforce aforesaid provisions.
Al. Compliance with Other Federal, State & Local Laws
A. The DEVELOPER covenants and warrants that it will comply with all applicable laws,
ordinances, codes, rules and regulations of the state local and federal governments, and
all amendments thereto.
B. Environmental review — All NSP -1 assistance is subject to the National Environmental
Policy Act of 1969 and related federal environmental authorities and regulations at 24
CFR Part 58.
1. A copy of the Environmental Review Record shall be maintained by both the
DEVELOPER and the GRANTEE.
C. Flood Disaster Protection — In accordance with the requirements of the Flood Disaster
Protection Act of 1973 (42 U.S.C. 4001), the DEVELOPER shall assure that for activities
located in an area identified by the Federal Emergency Management Agency (FEMA) as
having special flood hazards, flood insurance under the National Flood Insurance
Page 9 of 41
Program is obtained and maintained as a condition of financial assistance for acquisition
or construction purposes (including rehabilitation.)
D. Historic Preservation — The DEVELOPER agrees to comply with the Historic Preservation
requirements set forth in the National Historic Preservation Act of 1966, as amended (16
U.S.C. 470) and the procedures set forth in 36 CFR Part 800, Advisory Council on Historic
Preservation Procedures for Protection of Historic Properties, insofar as they apply to the
performance of this agreement.
E. The DEVELOPER agrees to comply with applicable state and local civil rights ordinances
and with Title VI of the Civil Rights Act of 1964 as amended, Title VIII of the Civil Rights
Act of 1968 as amended, Section 104(b) and Section 109 of Title I of the Housing and
Community Development Act of 1974 as amended (the HCDA), Section 504 of the
Rehabilitation Act of 1973, the Americans with Disabilities Act of 1990, the Age
Discrimination Act of 1975, Executive Order 11063, and Executive Order 11246 as
amended by Executive Orders 11375, 11478, 12107 and 12086, and will include the
provisions in every subcontract or purchase order, specifically or by reference, so that
such provisions will be binding upon each of its contractors and subcontractors.
F. The DEVELOPER agrees to comply with all applicable standards, orders, or requirements
issued under Section 306 of the Clean Air Act (42 U.S.C. 1857(h)), Section 508 of the
Clean Water Act (33 U.S.C. 1368), Executive Order 11738, and Environmental Protection
Agency regulations (40 CFR part 15).
G. The DEVELOPER agrees that no funds provided, nor personnel employed under this
Agreement, shall be in any way or to any extent engaged in the conduct of political
activities in violation of Chapter 15 of Title V of the United States Code. The
DEVELOPER is prohibited from using funds provided herein or personnel employed in the
administration of the program for inherently religious activities, lobbying, political
patronage, and nepotism activities.
H. Conflict of Interest — The provisions of 24 CFR 570.611, apply to the award of any
contracts under the agreement and the selection of buyers for NSP -1 -assisted units. No
member or Delegate to the Congress of the United States shall be permitted to any share
or part of this contract or any benefit hereunder. No member, officer or employee of the
GRANTEE; or its designees, or agents; or member of the GRANTEE Council of the
GRANTEE; and no other public official of the GRANTEE who exercises any functions or
responsibilities with respect to the program during his tenure or for one (1) year thereafter,
shall have any interest direct or indirect, in any contract or subcontract, or the proceeds
thereof, for work to be performed under this agreement. Exceptions must be requested by
the DEVELOPER and the GRANTEE may grant exceptions as permitted by Regulation.
VIII. Reporting, Monitoring & Access to Records
A. The DEVELOPER agrees to submit any and all reports required by HUD or the
GRANTEE. Additional reporting information is contained in Exhibit A-4 through A-7,
inclusive.
B. The DEVELOPER shall collect and maintain Project beneficiary information pertaining to
household size, income levels, racial characteristics, and the presence of Female Headed
Households in order to determine low and moderate -income benefit in a cumulative and
Individual manner. Income documentation shall be in a form consistent with NSP -1
requirements.
Page 10 of 41
C. The DEVELOPER agrees to provide the GRANTEE access to records and projects at any
time during project implementation or for five years after project closeout for purposes of
verifying compliance with NSP -1 requirements and this agreement. Access shall be
immediately granted to the GRANTEE, HUD, the Comptroller General of the United
States, or any of their duly authorized representatives to any books, documents, papers,
and records of the DEVELOPER or its contractors which are directly pertinent to that
specific contract for the purpose of making audit, examination, excerpts, and
transcriptions.
D. The GRANTEE reserves the right to audit the records of the DEVELOPER any time
during the performance of this Agreement and for a period of five years after final payment
is made under this Agreement. If required by A-133, the DEVELOPER will provide the
GRANTEE with a certified audit of the DEVELOPER's records representing the Fiscal
Year during which the PROJECT becomes complete.
E. Project Closeout — The DEVELOPER's obligation to the GRANTEE shall not end until all
close-out requirements are completed. Activities during this close-out period shall
include, but are not limited to: making final payments, accounting for use of funds,
provision of all reports and records required by the GRANTEE.
IX. Suspension & Termination
In accordance with 24 CFR 85.43, suspension or termination may occur if the DEVELOPER
materially falls to comply with any term of the award, and that the award may be terminated for
convenience in accordance with 24 CFR 85.44.
A. If the DEVELOPER fails in any manner to fully perform and carry out any of the terms,
covenants, and conditions of the agreement, or if the DEVELOPER refuses or fails to
proceed with the work with such diligence as will insure its completion within the time fixed
by the schedule set forth in this agreement, the DEVELOPER shall be in default and
notice in writing shall be given to the DEVELOPER of such default by the GRANTEE or an
agent of the GRANTEE. If the DEVELOPER fails to cure such default within such time as
may be required by such notice, the GRANTEE may, at its option, terminate and cancel
the contract.
1. In the event of such termination, all funds awarded to the DEVELOPER pursuant to
this agreement shall be immediately revoked and any approvals related to the
PROJECT shall immediately be deemed revoked and canceled. In such event, the
DEVELOPER will no longer be entitled to receive any compensation for work
undertaken after the date of the termination of this agreement, as the grant funds
will no longer be available for this project.
2. In such event, the DEVELOPER shall be entitled to receive just and equitable
compensation for any work satisfactorily completed hereunder to the date of said
termination.
3. Notwithstanding the above, the DEVELOPER shall not be relieved of liability to the
GRANTEE for damages sustained by the GRANTEE by virtue of any breach of the
contract by the DEVELOPER and the GRANTEE may withhold any payments to the
DEVELOPER for the purpose of setoff until such time as the exact amount of
damages due the GRANTEE from the DEVELOPER is determined whether by court
of competent jurisdiction or otherwise.
Pagel 1 of 41
4. Such termination shall not effect or terminate any of the rights of the GRANTEE as
against the DEVELOPER then existing, or which may thereafter accrue because of
such default, and the foregoing provision shall be in addition to all other rights and
remedies available to the GRANTEE under the law and the note and mortgage (if in
effect), including but not limited to compelling the DEVELOPER to complete the
project in accordance with the terms of this agreement, In a court of equity.
5. The waiver of a breach of any term, covenant or condition hereof shall not operate
as a waiver of any subsequent breach of the same or any other term, covenant, or
condition hereof.
The GRANTEE may terminate for its convenience this contract at any time by giving at
least thirty (30) days notice in writing to the DEVELOPER. If the contract is terminated by
the GRANTEE, as provided herein, the GRANTEE will reimburse for any actual and
approved expenses incurred, including those costs involved in terminating the contracts
and shutting down the work as of the date of notice, and the DEVELOPER will be paid as
compensation an amount which bears the same ratio to the total compensation as the
services actually performed bear to the total service of the DEVELOPER covered by this
contract, less payments of compensation previously made.
Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any such
disputes by negotiation. The negotiation shall be attended by representatives of
CONSULTANT with full decision-making authority and by OWNER'S staff person who
would make the presentation of any settlement reached during negotiations to OWNER for
approval. Failing resolution, and prior to the commencement of depositions in any
litigation between the parties arising out of this Agreement, the parties shall attempt to
resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator
certified by the State of Florida. The mediation shall be attended by representatives of
CONSULTANT with full decision-making authority and by OWNER'S staff person who
would make the presentation of any settlement reached at mediation to OWNER'S board
for approval. Should either party fail to submit to mediation as required hereunder, the
other party may obtain a court order requiring mediation under Section 44.102, Fla. Stats.
Any suit or action brought by either party to this Agreement against the other party relating
to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all
such matters.
X. General Conditions
A. All notices or other communication which shall or may be given pursuant to this
Agreement shall be in writing and shall be delivered by personal service, or by registered
mail addressed to the other party at the address indicated herein or as the same may be
changed from time to time. Such notice shall be deemed given on the day on which
personally served; or, if by mail, on the fifth day after being posted or the date of actual
receipt, whichever is earlier.
Page 12 of 41
GRANTEE
Collier County Board of County Commissioners
ATTN: Housing, Human and Veteran Services
3339 Tamiami Trail E, Suite 211
Naples, Florida 34112
With a Copy to:
Collier County Office of County Attorney
ATTN: Jennifer White
3299 Tamlami Trail E, Suite 800
Naples, Florida 34112
DEVELOPER
Habitat for Humanity of Collier County, Inc.
11145 Tamlami Trail East
Naples, Florida 34113
B. Title and paragraph headings are for convenient reference and are not a part of this
Agreement.
C. In the event of conflict between the terms of this Agreement and any terms or conditions
contained in any attached documents, the terms in this Agreement shall rule.
D. No waiver or breach of any provision of this Agreement shall constitute a waiver of a
subsequent breach of the same or any other provision hereof, and no waiver shall be
effective unless made in writing.
E. The GRANTEE's failure to act with respect to a breach by the DEVELOPER does not
waive its right to act with respect to subsequent or similar breaches. The failure of the
GRANTEE to exercise or enforce any right or provision shall riot constitute a waiver of
such right or provision.
F. The parties hereto agree that this Agreement shall be construed and enforced according
to the laws of the State of Florida.
G. Should any provisions, paragraphs, sentences, words or phrases contained in this
Agreement be determined by a court of competent jurisdiction to be invalid, illegal or
otherwise unenforceable under the laws of the State of Florida or the GRANTEE, such
provisions, paragraphs, sentences, words or phrases shall be deemed modified to the
extent necessary in order to conform with such laws, or if not modifiable to conform with
such laws, then same shall be deemed severable, and in either event, the remaining
terms and provisions of this Agreement shall remain unmodified and in full force and
effect.
H. The obligations undertaken by DEVELOPER pursuant to this Agreement shall not be
delegated or assigned to any other person or agency unless GRANTEE shall first consent
to the performance or assignment of such service or any part thereof by another person or
agency.
The Agreement shall be binding upon the parties hereto, their heirs, executors, legal
representative, successors and assigns.
Page 13 of 41
J. DEVELOPER shall indemnify and save GRANTEE harmless from and against any
negligent claims, liabilities, losses and causes of action which may arise out of
DEVELOPER's activities under this Agreement, including all other acts or omissions to act
on the part of DEVELOPER, including any person acting for or on its behalf, and, from
and against any orders, judgments, or decrees which may be entered and from and
against all costs, attorneys fees, expenses and liabilities incurred in the defense of any
such claims, or in the investigation thereof.
K. DEVELOPER and its employees and agents shall be deemed to be independent
contractors, and not agents or employees of the GRANTEE, and shall not attain any rights
or benefits under the civil service or pension ordinances of the GRANTEE, or any rights
generally afforded classified or unclassified employee; further they shall not be deemed
entitled to state Compensation benefits as an employee of the GRANTEE.
L. Funding for this Agreement is contingent on the availability of funds and continued
authorization for program activities and is subject to amendment or termination due to lack
of funds, or authorization, reduction of funds, and/or change in regulations.
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first
above written.
t.5"(t b ot
ATTEST
Dwigh E. Brock, Clerk of Courts
N(
Dated: S`
Att�SEEAL)
st%011 .,t'd-Chaltew
App�f~. •and
legal sufficiency:
Assistant County Attorney
First Witness
R) i`c (, !Krlc1(a �Aet- 1 s
T pe/print xVitiness name
Second Witness
Type/print witness name
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
By:
Fred W. Coyle, Chairman/2 y -io
Habitat for Humanity of Collier County, Inc.
A Florida not-for-p-rofit cwporatjen%
By:
Print:
Title:
Page 14 of 41
EXHIBIT A. Project Description
A. GENERAL
Developer will be provided ownership in certain real property acquired by the Grantee for
the purpose of rehabilitation or redevelopment for disposition to NSP -eligible persons or
families. The forty-two (42) properties associated with this Agreement consist of twenty-
one (21) single-family residential dwelling units, eleven (11) two -to -four unit residential
dwelling units, and ten (10) vacant residential parcels. The properties associated with
this Agreement are more particularly described in Exhibit A-1. All costs associated with
the transfer for the aforementioned properties from Grantee to Developer shall be borne
by Developer.
B. ELIGIBLE ACTIVITIES
The following activities are eligible under this Agreement and are more thoroughly
described in the NSP Notice.
a. NSP -Eligible Use (A) -- Establish financing mechanisms for purchase and
redevelopment of foreclosed upon homes and residential properties, including
such mechanisms as soft -seconds, loan loss reserves, and shared -equity loans
for low- and moderate -income homebuyers.
• As part of an activity delivery cost for an eligible activity as defined in 24 CFR
570.206.
• Also, the eligible activities listed below to the extent financing mechanisms
are used to carry them out.
b. NSP -Eligible Use (B) — Purchase and rehabilitate homes and residential
properties that have been abandoned or foreclosed upon, in order to sell, rent, or
redevelop such homes and properties.
24 CFR 570.201(a) Acquisition, (b) Disposition, (i) Relocation, and (n) Direct
homeownership assistance (as modified below):
0 24 CFR 570.202 eligible rehabilitation -and preservation activities for
homes and residential properties.
o HUD notes that any of the activities listed above may include required
homebuyer counseling as an activity delivery cost.
c. NSP -Eligible Use (C) — Establish and operate land banks for homes and
residential properties that have been foreclosed upon.
• 24 CFR 570.201(a) Acquisition and (b) Disposition
o HUD notes that any of the activities listed above may include required
homebuyer counseling as an activity deliver cost.
d. NSP -Eligible Use (D) — Demolish blighted structures.
• 24 CFR 570.201(d) Clearance for blighted structures only.
e. NSP -Eligible Use (E) — Redevelop demolished or vacant properties as housing.
Page 15 of 41
24 CFR 570.201(a) Acquisition, (b) Disposition, (c) Public facilities and
improvements, (e) Public services for housing counseling, but only to the
extent that counseling beneficiaries are limited to prospective purchasers or
tenants of the redeveloped properties, (i) Relocation, and (n) Direct
homeownership assistance (as modified below):
0 24 CFR 570.202 Eligible rehabilitation and preservation activities for
demolished or vacant properties.
0 24 CFR 570.204 Community based development organizations.
o HUD notes that any of the activities listed above may include required
homebuyer counseling as an activity delivery cost.
C. REHABILITATION OR REDEVELOPMENT
NSP -assisted property subject to this Agreement shall be rehabilitated or redeveloped to
the extent necessary to comply with applicable laws, codes, and other requirements
relating to housing safety, quality, and habitability in order to sell, rent, or redevelop such
homes and properties. Developer led rehabilitation is undertaken pursuant to 24 CFR
570.202(b)(1). New housing construction is undertaken pursuant to 24 CFR 570.204, or
the NSP notice published on October 6, 2008, as amended.
Pursuant to the Grantee's NSP -1 action plan, NSP -assisted property is required to meet
or exceed local and state building codes; the current code applied in Collier County is
2007 Florida Building Code. Furthermore, HERA defines rehabilitation to include
improvements to increase the energy efficiency or conservation of such homes and
properties or to provide a renewable energy source or source for such homes and
properties. Such improvement are also eligible under the regular CDBG program.
Developer is subject to Section 504 of the Rehabilitation Act of 1973 and the Fair
Housing Act, including their respective provisions related to physical accessibility
standards for person with disabilities. See 24 CFR Part 8; 24 CFR 100.205; See also 24
CFR 570.487 and 24 CFR 570.602.
D. LAND BANK PROPERTIES
An NSP -assisted property may not be held in a land bank for more than 10 years without
obligating the property for a specific, eligible redevelopment of that property in
accordance with NSP requirements. Properties may be used for a development -related
purpose, or for a non -development use in conformance with NSP regulations. Potential
non -development uses may include urban agriculture, habitat restoration, reforestation,
expansion of parklands, or other allowable options.
Developer may elect to redevelop the land bank properties associated with this
agreement, or employ a non -development use in conformance with NSP regulations.
E. ELIGIBLE INCOME LEVELS OF BUYERS
NSP -assisted property subject to the Agreement shall be used with respect to individuals
and families whose income does not exceed 120 percent of area median income.
However, not less than twenty-five (25) percent of the funds expended by Grantee in
acquiring the properties subject to this Agreement shall be used to house individuals or
families whose income do not exceed 50 percent of the area median income ("LH25
Requirement').
Page 16 of 41
To ensure compliance with the NSP LH25 Requirement, the following coordinated effort
shall be used:
Grantee shall provide to Developer, within 60 days of final execution of
Agreement
o Amount of funds expended by Grantee on the properties subject to
this Agreement that must be used to house individuals or families
whose income no not exceed 50 percent of the area median income;
o Amount of NSP funds invested per property subject to this Agreement
• Developer shall provide Grantee, within 60 days from receipt of the above
information
o Which properties shall be designated for the benefit of individuals or
families whose income does not exceed 50 percent of the area
median income
Taken together, these actions will ensure that Grantee complies with the NSP LH25
Requirement and such resulting property designations shall become a part of this
Agreement.
F. MAXIMUM SALES PRICE
If an abandoned or foreclosed -upon home or residential property is purchased,
redeveloped, or otherwise sold to an individual as a primary residence, then such sale
shall be in amount equal to or less than the cost to acquire and redevelop or rehabilitate
such property up to a decent, safe, and habitable condition. The maximum sales price
for a property is determined by aggregating all costs of acquisition, rehabilitation, and
redevelopment (including related activity delivery costs, which generally include, among
other things, costs related to the sale of the property). Note that the maximum sales
price may not exceed the current market value of the unit as established by an appraisal.
G. HABITAT FOR HUMANITY AFFILIATES
Grantee hereby designates Habitat for Humanity of Collier County, Inc. as a Developer
of the County's NSP. Pursuant to a HUD issued NSP Policy Alert titled "Guidance for
Habitat for Humanity Affiliates," dated January 12, 2011, the following clarifications are
hereby provided.
a. DEVELOPER
Developers are program beneficiaries and thus distinct from subrecipients,
grantee employees, and contractors. Developers may receive NSP funds from
the Grantee. Developer -led rehabilitation is undertaken pursuant to 24 CFR
570.202(b)(1). New housing construction is undertaken pursuant to 24 CFR
570.204, or the NSP notice published on October 6, 2008, as amended.
Habitat for Humanity affiliates designated as developers:
• Do not have to follow federal procurement rules;
May charge developer fees;
• Do not have to follow OMB Circulars;
Page 17 of 41
• Are not required to treat revenues as program income
b. SALES PRICE VALUATION
In addition to the information contained above under "Maximum Sales Price," the
cost of donated materials and professional services may also be included in the
base for determining the maximum sales price under Section 2301(d)(3) of
HERA. The cost of donated materials must be based on fair market value at the
time of donation. Estimates of the value of unskilled or sweat -equity labor may
not be included in the total development cost. Moreover, the costs of donated
professional services and materials may not be reimbursed by the NSP grant.
c. DEVELOPMENT SUBSIDY
In some instances, the total development cost of rehabbed and/or newly
constructed NSP units will be greater than the current market value of such unit.
In such situations, NSP funds can be used to fill the appraisal gap, and will be
considered a development subsidy. Grantee may not apply affordability
instruments to NSP funds used as a development subsidy. This subsidy will be
considered a "sunk cost" and is considered an eligible use of NSP funds.
d. DETERMINATION OF NO UNDUE ENRICHMENT
Pursuant to the terms and conditions of this Agreement, Developer shall be
investing Developer's own funds, time, and effort when undertaking the project
described herein. Furthermore, Developer is a not-for-profit provider of
affordable housing. Based upon these facts, as well as the rules and regulations
applicable to NSP, Grantee has determined that there is no undue enrichment
should Developer recapture and retain the net proceeds from sale of properties
assisted through this Agreement.
H. INDEMNIFICATION
To the maximum extent permitted by Florida law, the Developer shall indemnify and hold
harmless Collier County, its officers and employees from any and all liabilities, damages,
losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals'
fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Developer or anyone employed or utilized by the Developer in the
performance of this Agreement. This indemnification obligation shall not be construed to
negate, abridge or reduce any other rights or remedies which otherwise may be
available to an indemnified party or person described in this paragraph. This section
does not pertain to any incident arising from the sole negligence of Collier County. The
foregoing indemnification shall not constitute a waiver of sovereign immunity beyond the
limits set forth in Section 768.28, Florida Statutes.
I. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES
No organization or individual shall offer or give, either directly or indirectly, any favor, gift,
loan, fee, service or other item of value to any County employee, as set forth in Chapter
112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, and County
Administrative Procedure 5311. Violation of this provision may result in one or more of
the following consequences: a. Prohibition by the individual, firm, and/or any employee
Page 18 of 41
of the firm from contact with County staff for a specified period of time; b. Prohibition by
the individual and/or firm from doing business with the County for a specified period of
time, including but not limited to: submitting bids, RFP, and/or quotes; and, c, immediate
termination of any contract held by the individual and/or firm for cause.
J. COSTS ASSOCIATED WITH THE CONVEYANCE OF PROPERTY
Each party shall be responsible for payment of its own attorney's fees. The Developer
shall be responsible for payment of the cost of recording the Statutory Deed(s) and the
pro -rata share of the water, sewer, and garbage charges. The Developer shall be
responsible to transfer associated utility accounts within 48 hours after the day of
closing.
Page 19 of 41
EXHIBIT A-1. Legal Descriptions
The following site-specific list of properties is associated with this Agreement and ownership to
such will be transferred from Grantee to Developer following all standard Collier County closing
procedures.
1. Lot 52, Block B, Whispering Pines, a Subdivision of Lots 48 and 49 in Naples Grove and
Truck Company's Little Farms #2, according to the Plat Thereof, as Recorded in Plat
Book 4, Page 17, of the Public Records of Collier County, Florida. Parcel No.
81732120002 (2842 Barrett Avenue, Naples, FL 34112)
2. Lot 20, in Block 9, of Naples Manor Addition, according to the Plat thereof, as recorded
in Plat Book 3, at Pages 67 and 68, of the Public Records of Collier County, Florida.
Parcel No. 62097920005 (5378 Carlton Street, Naples, FL 34113)
3. Lot 5, Block 12, Naples Manor Lakes, according to the plat thereof, recorded in Plat
Book 3, Pages 86 and 87, of the Public Records of Collier County, Florida; Parcel No.
62261280005 (5318 Gilchrist Street, Naples, FL 34113)
4. Lot 6, Block 12, Naples Manor Lakes, according to the plat thereof, recorded in Plat
Book 3, Pages 86 and 87, of the Public Records of Collier County, Florida. Parcel No.
62261320004 (5322 Gilchrist Street, Naples, FL 34113)
5. Lot 7, Block 12, Naples Manor Lakes, according to the plat thereof, recorded in Plat
Book 3, Pages 86 and 87, of the Public Records of Collier County, Florida. Parcel No.
62261360006 (5326 Gilchrist Street, Naples, FL 34113)
6. Lot 8, Block 12, Naples Manor Lakes, according to the plat thereof, recorded in Plat
Book 3, Pages 86 and 87, of the Public Records of Collier County, Florida. Parcel No.
62261400005 (5330 Gilchrist Street, Naples, FL 34113)
7. Lot 9, Block 12, Naples Manor Lakes, according to the plat thereof, recorded in Plat
Book 3, Pages 86 and 87, of the Public Records of Collier County, Florida. Parcel No.
62261440007 (5334 Gilchrist Street, Naples, FL 34113)
8. Lot 10, Block 12, Naples Manor Lakes, according to the plat thereof, recorded in Plat
Book 3, Pages 86 and 87, of the Public Records of Collier County, Florida. Parcel No.
62261480009 (5340 Gilchrist Street, Naples, FL 34113)
9. Lot 19, Block A, Pine -View Villas, according to the Plat thereof, recorded in Plat Book 9,
Page 49, of the Public Records of Collier County, Florida. Parcel No. 67490760003
(4308 Rose Avenue, Naples, FL 34112)
10. Lot 3, and the East 28 Feet of Lot 4, Block 3, Burdale, according to the Map or Plat
thereof, as recorded in Plat Book 4, Page 2, of the Public Records of Collier County,
Florida. Parcel No. 25081280002 (2522 Linwood Avenue, Naples, FL 34112)
11. Lot 33, Block 188, Golden Gate, Unit 6, according to the Plat thereof, as recorded in Plat
Book 5, Pages 124- 134, of the Public Records of Collier County, Florida. Parcel No.
36304720005 (2049 55th Terrace SW, Naples, FL 34116)
Page 20 of 41
12. The West 75 Feet of the West 150 Feet of Tract No. 90, Golden Gate Estates, Unit No.
42, according to the Map or Plat thereof, as recorded in the Plat Book 7, Page 27, of the
Public Records of Collier County, Florida. Parcel No. 38847800008 (2860 64`x' Avenue
NE, Naples, FL 34120)
13. The West 75 Feet of the West 150 Feet of Tract 79, Golden Gate Estates, Unit No. 42,
according to the Plat thereof, as recorded in Plat Book 7, Page 27, of the Public Records
of Collier County, Florida. Parcel No. 38846560006 (2765 58th Avenue NE, Naples, FL
34120)
14. The West 75 Feet of Tract 85, Golden Gate Estates, Unit 72, according to the Map or
Plat thereof, as recorded in Plat Book 5, Page 8, Public Records of Collier County,
Florida. Parcel No. 40419040006 (4460 22nd Avenue NE, Naples, FL 34120)
15. Lot 19 and the East Half of Lot 20, Avalon Estates Replat of Unit No. 1, a Subdivision
According to the Map or Plat Thereof, as recorded in Plat Book 4, Page 65, of the Public
Records of Collier County, Florida. Parcel No. 22670520008 (3614 Poplar Way, Naples,
FL 34112)
16. Lot 8, Block 59, Golden Gate, Unit 2, according to the Plat Thereof, recorded in Plat
Book 5, Pages 65 through 77, of the Public Records of Collier County, Florida. Parcel
No. 35774280008 (2197 44`" Terrace SW, Naples, FL 34116)
17. The West 75 Feet of the East 180 Feet of Tract 90, Golden Gate Estates, Unit No. 62,
according to the Plat thereof, as recorded in Plat Book 5, Page 87, of the Public Records
of Collier County, Florida. Parcel No. 39781520003 (3685 418t Avenue NE, Naples, FL
34120)
18. The West 75 Feet of the East 180 Feet of Tract 43, Golden Gate Estates, Unit No. 71,
According to the Plat thereof, recorded in Plat Book 5, Page 7, of the Public Records of
Collier County, Florida. Parcel No. 40355240009 (3380 20th Avenue NE, Naples, FL
34120)
19. Lot 21, Block 172, Golden Gate, Unit 5, According to the Plat thereof, as Recorded in
Plat Book 5, Pages 117 through 123, inclusive, of the Public Records of Collier County,
Florida. Parcel No. 36245160009 (1853 51S` Terrace SW, Naples, FL 34116)
20. Lot 17, Block 121, Golden Gate, Unit 4, according to the plat thereof, recorded in Plat
Book 5, Pages 107 to 116, inclusive, of the Public Records of Collier County, Florida.
Parcel No. 36113200004 (4913 22nd Place SW, Naples, FL 34116)
21. Lot 8, Block 4, Naples Manor Lakes, according to the Plat thereof, as recorded in Plat
Book 3, Page 86, of the Public Records of Collier County, Florida. Parcel No.
62252520004 (5230 Gilchrist Street, Naples, FL 34113)
22. Lot 22, Block 185, Golden Gate, Unit 6, according to the Plat thereof, of record in Plat
Book 5, Pages 124 through 134, of the Public Records of Collier County, Florida. Parcel
No. 36300880004 (2180 52nd Terrace SW, Naples, FL 34116)
23. Lot 11, Block 135, Golden Gate, Unit 4, according to the Plat thereof, recorded in Plat
Book 5, Page 112, of the Public Records of Collier County, Florida. Parcel No.
36122520005 (4833 21St Avenue SW, Naples, FL 34116)
Page 21 of 41
24. Lot 23, Block 240, Golden Gate, Unit 7, according to the map or plat thereof, on file and
recorded with the Clerk of the Circuit Court and recorded at Plat Book 5, Page 141,
Public Records of Collier County, Florida. Parcel No. 36439240007 (3025 52" Street
SW, Naples, FL 34116)
25. Lot 5, Block 56, Golden Gate, Unit 2, according to the plat thereof, as recorded in Plat
Book 5, Pages 65 through 77, inclusive, of the Public Records of Collier County, Florida.
Parcel No. 35772680008 (4440 19th Avenue SW, Naples, FL 34116)
26. Lot 11, Block 45, Unit 2, Golden Gate, , according to the plat thereof, as recorded in Plat
Book 5, Pages 65 through 77, inclusive, of the Public Records of Collier County, Florida.
Parcel No. 35764920006 (4300 17`h Avenue SW, Naples, FL 34116)
27. Lot 24, Block 167, Golden Gate, Unit No. 5, according to the plat thereof, as recorded in
Plat Book 5, Pages 117 through 123, of the Public Records of Collier County, Florida.
Parcel No. 36241760005 (2100 51St Terrace SW, Naples, FL 34116)
28. Lot 33, Block 218, Golden Gate, Unit 6 Part 1, according to the plat thereof, as recorded
in Plat Book 9, Pages 1 through 7, inclusive, of the Public Records of Collier County,
Florida. Parcel No. 36383680001 (5401 21St Place SW, Naples, FL 34116)
29. Lot 11, COL -LEE -CO Gardens, according to the Plat thereof, as recorded in Plat Book 1,
Page 30, of the Public Records of Collier County, Florida. Parcel No. 26830320002
(2972 Gordon Street, Naples, FL 34112)
30. Lot 5, Block D, South Tamiami Heights, according to the Plat thereof, recorded in Plat
Book 3, Page 44, of the Public Records of Collier County, Florida; Parcel No.
74412200000 (3511 Okeechobee Street, Naples, FL 34112)
31. Lot 10, Block 259, Golden Gate, Unit 7, according to the Plat thereof, recorded in Plat
Book 5, Pages 135 through 146, inclusive, of the Public Records of Collier County,
Florida. Parcel No. 36450840004 (4914 30th Place SW, Naples, FL 34116)
32. Lot 33, Block 5 of Trail Acres, according to the Plat thereof, as recorded in Plat Book 3,
Page(s) 50, of the Public Records of Collier County, Florida. Parcel No. 77214040009
(158 51h Street, Naples, FL 34114)
33. The West Half (West '/2) of the Northwest Quarter (Northwest '/) of the Northeast
Quarter (Northeast'/) of the Northwest Quarter (Northwest'/) of the Southwest Quarter
(Southwest'/) of Section 16, Township 50 South, Range 26 East, Less the Northerly 30
feet thereof, Public Records of Collier County, Florida. Parcel No. 00418760000 (6067
Polly Avenue, Naples, FL 34112)
34. Lot 2, Block 192, Golden Gate, Unit 6, according to the plat thereof, recorded in Plat
Book 5, Page 130, of the Public Records of Collier County, Florida. Parcel No.
36308560009 (5418 23`d Court SW, Naples, FL 34116)
35. Lot 25, Block 76, Golden Gate, Unit 2, according to the Plat thereof, as recorded in Plat
Book 5, Page(s) 65- 77, of the Public Records of Collier County, Florida. Parcel No.
35780960008 (2183 41St Street SW, Naples, FL 34116)
Page 22 of 41
36. Lot 58, Hallendale, according to the map or plat thereof, as recorded in Plat Book 4,
Page(s) 25, Public Records of Collier County, Florida. Parcel No. 48782160000 (No Site
Address)
37. Lot 59, Hallendale, according to the map or plat thereof, as recorded in Plat Book 4,
Page(s) 25, Public Records of Collier County, Florida. Parcel No. 48782200009 (No Site
Address)
38. Lot 63, Hallendale, according to the map or plat thereof, as recorded in Plat Book 4,
Page(s) 25, Public Records of Collier County, Florida. Parcel No. 48782320002 (No Site
Address)
39. Lot 20, Block 6, Avalon Estates, Unit No. 1, according to the Map of the Plat thereof, as
recorded in Plat Book 3, Page 62, of the Public Records of Collier County, Florida.
Parcel No. 22624480107 (No Site Address)
40. Lot 18, Block 6, Avalon Estates, Unit No. 1, according to the Plat thereof, as recorded in
Plat Book 3, Page 62, of the Public Records of Collier County, Florida. Parcel No.
22624440008 (4561 Dominion Drive, Naples, FL 34112)
41. The West'/2 of Lot 10 and All of Lots 11 & 12, Block C, Whispering Pines, According to
the Plat Thereof, as Recorded in Plat Book 4, Page 17, Public Records of Collier
County, Florida. Parcel No. 81732480001 (2742 Storter Avenue, Naples, FL 34112)
42. The East 180 Feet of Tract 91, Golden Gate Estates, Unit No. 42, according to the Plat
thereof, of record in Plat Book 7, Page 27, of the Public Records of Collier County,
Florida. Parcel No. 38848000001 (2883 62nd Avenue NE, Naples, FL 34120)
Page 23 of 41
EXHIBIT A-2. Affordability Requirements
GENERAL
Developer will ensure that all properties subject to this Agreement comply with the affordability
provisions of the HOME Investment Partnerships Program as contained in 24 CFR 92.254
relating to qualification as affordable housing for homeownership. The Developer, at its sole
discretion, may impose greater restrictions so long as the restrictions are at level at or above
those of the HOME Investment Partnerships Program.
HOMEOWNERSHIP: LONG TERM AFFORDABILITY
The NSP -assisted housing must meet the affordability requirements for not less than the
applicable period specified in the following table, beginning after project completion. The per
unit amount of NSP funds and the affordability period that they trigger are described more fully
below under Recapture Provisions.
Homeownership assistance NSP Minimum period of
amountper-unit affordabilit in years
Under $15,000 ........................... 5
$15,000 to $40,000 ...................... 10
Over $40,000..........1 ................... 15
Recapture Provisions
The recapture provisions will ensure that the Developer recoups all or a portion of the NSP
assistance benefiting the homebuyer, if the housing does not continue to be the principal
residence of the family for the duration of the period of affordability. The period of affordability is
based upon the total amount of NSP funds subject to recapture described above.
The Developer may choose to recapture the entire amount of NSP assistance or a reduced
amount on a prorata basis for the time the homeowner has owned and occupied the housing
measured against the required affordability period. The net proceeds may be divided
proportionally as set forth in the following mathematical formulas:
NSP investment X Net proceeds = NSP amount to Developer
NSP investment + homeowner investment
homeowner investment X Net proceeds = amount to homeowner
NSP investment + homeowner investment
The Developer may permit the homebuyer to recover the homebuyer's entire investment (down
payment and capital improvements made by the owner since purchase) before recapturing the
NSP investment. Any NSP investment recaptured by the Developer shall remain with the
Developer for future use toward other NSP -eligible activities.
Page 24 of 41
EXHIBIT A-3. Developer Fee
GENERAL
Developer shall invest its own funds to complete the rehabilitation or development of the
properties associated with this Agreement thereby assuming risk associated with the project.
To compensate Developer for such risk, and for providing NSP -related goods and services,
such as, but not necessarily limited to, residential rehabilitation, eligible buyer identification, and
final disposition, Developer shall be paid a developer fee.
AMOUNT
Grantee shall pay Developer a Five Thousand Five Hundred and 00/100 Dollars ($5,500)
developer fee for each of the forty-two (42) properties associated with this Agreement. The
maximum combined developer fee paid by Grantee to Developer through this Agreement shall
be Two Hundred Thirty One Thousand and 00/100 Dollars ($231,000); this amount represents a
cumulative of developer fees paid for each of the properties associated with this Agreement.
METHOD OF PAYMENT
Grantee shall pay Developer the developer fee per property upon final sale to an income -eligible
person or household. To secure payment, Developer shall submit to Grantee the following
supporting materials in a format acceptable to Grantee:
1. HUD -1 Settlement Statement
2. Appraisal
3. Sales Contract
4. Attestation form to be provided by Grantee
Page 25 of 41
EXHIBIT A-4. Grant Agency Requirements
APPLICABLE LAWS AND REGULATIONS
Certain State and Federal laws, regulations, and Executive Orders are applicable in part or in
whole to the NSP. The applicable laws, regulations, and Executive Orders, classified generally
by compliance area, include but may not be limited to the following.
GENERAL REQUIREMENTS
The Housing and Community Development Act of 1974, as amended and as
implemented by the most current HUD regulations (24 CFR Part 570).
Federal Register Docket No. FR -5447-N-01: Notice of Formula Allocations and Program
Requirements for Neighborhood Stabilization Program Formula Grants; October 19, 2010.
U.S. Department of Housing and Urban Development's Playing by the Rules: A Handbook
for CDBG Sub -recipients on Administrative Systems,
CIVIL RIGHTS
• Title VI - Civil Rights Act of 1964.
• Section 109 - Title I - Housing and Community Act of 1974.
• Title VIII of the Civil Rights Act, 1968 (Fair Housing Act), as amended. 42 U.S.C. 3601.
• Section 504 of the Rehabilitation Act of 1973, and the Americans with Disabilities Act of
1990.
• Executive Order 11246 - Equal Employment Opportunity, as amended by Executive
Order 11375, Parts II and Ill.
• Executive Order 11063 - Equal Employment Opportunity, as amended by Executive
Order 12259.
• Section 3 of the Housing and Development Act of 1968, as amended Section 118 of Title
I, Community Development and Housing Act, 1974.
• Age Discrimination Act of 1975.
• Executive Order 12432: National Priority to Develop Minority and Women Owned
Businesses.
• Section 504 of the Rehabilitation Act of 1973 and implementation regulation (24 CFR
Part 8).
ACQUISITION AND RELOCATION
• The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970
(46 U.S.C. 4601 and regulations at 49 CFR, Part 24).
HOUSING
• The Truth in Lending Act (Regulation Z).
• Title I Consumer Protection Act (PL 90321).
• The Lead Base Paint Poisoning Prevention Act (42 U.S.C. 4831-5 et al.) and HUd
implementing regulations (24 CFR Part 35).
• The Residential Lead -Based Paint Hazard Reduction Act of 1993 (PL 102-550).
• The National Manufactured Housing Construction and Safety Standards Act of 1974 (42
U.S.C., 5401 et. seq., as amended).
• Manufactured Housing Act (O.C.G.A. Sections 8-2-130 and 160 et. seq.).
Page 26 of 41
• Construction Industry Licensing Board Act (O.C.G.A. Section 43-14-8).
• The Fire Administration Authorization Act of 1992 (PL 102-522).
ENVIRONMENTAL
• Title I of the Housing and Community Development Act, Section 104(g) — as amended
(42 U.S.C. 5304) and published in 24 CFR Part 58.
• Section 306 of the Clear Air Act (42 U.S.C. 1857(h))
• Section 508 of the Clean Water Act (33 U.S.C. 1368).
• Executive Order 11738, and Environmental Protection Agency regulations (40 CFR part
15).
• Energy Policy and Conservation Act (Pub. L.94-163).
LABOR STANDARDS
• The Contract Work Hours and Safety Standards Act (40 U.S.C. 327-330) as
supplemented by Department of Labor regulations.
• The Davis -Bacon Act (40 U.S.C. 276(a) to (a-7), as supplemented by Department of
Labor Regulations.
• The Davis -Bacon Act (42 U.S.C. 5310).
• The Copeland "Anti -Kickback" Act (18 U.S.C. 874) as supplemented by Department of
Labor regulations.
Mug
• Conditions prohibiting inherently religious activities (24 CFR 570.2000)).
HOUSING REHABILITATION REQUIREMENTS
• The Common Rule 24 CFR 85 — applies if the direct party of the construction contract.
This rule requires a competitive procurement.
• Federal Labor Standards — Only in certain situations. Davis -bacon wage rate are
applicable when NSP funds are used for rehabilitation of more than 8 housing units in
one project.
• Lead -Based Paint Hazard Elimination (24 GFR Part 35) — These rules include
inspection, testing, risk assessments, hazard control or abatement, safe work practices,
clearance and notification/disclosure requirements.
• Section 3 Clause of the Urban Development Act of 1968, and as implemented by HUD
regulations at 24 CFR Part 135 applies (regardless of the dollar amount of the contract)
in the following situations:
o If the Recipient contracts directly for rehabilitation services or acts as an agent
for the homeowner, i.e., signs the rehabilitation contract.
o If the Recipient provides homeowners with a list of contractors eligible to
participate in the local rehabilitation program, the Recipient should assure that
eligible Section 3 business concerns located or owned in part by residents of the
area are also included on the list.
o If the individual homeowner contracts directly for rehabilitation services and the
Recipient is not a party to the contract, the Section 3 requirements do not have to
be followed.
• Section 104(4) of the Housing and Community Development Act is applicable if rental
units are converted to non- 'low and moderate income dwelling units" or if occupied or
Page 27 of 41
occupiable housing units are demolished. See HUD regulations at 24 CFR Part 570.606
and 24 CFR Part 42.
The Uniform Relocation Assistance and Real Property Acquisition Act of 1970, as
amended, and as implemented by DOT regulations 49 CFR Part 24, is applicable if
tenants or homeowners (regardless of income) are displaced in conjunction with a NSP
activity.
The Truth -In -Lending Act (Regulation Z) (USC 1601, et. seq.) which applies to any loan
transaction between the Recipient and the homeowner provided the Recipient meets the
criteria of being a "creditor", as defined by the Federal Reserve System
EQUAL OPPORTUNITY, FAIR HOUSING, AND ACCESSIBILITY
_i_ MI1
The regulations pursuant to Title I of the Housing and Community Development Act require
applicants to assure through certification that all activities will be conducted in accordance with
Section 109 of the Act (the nondiscrimination clause), Title VI of the Civil Rights Act of 1964,
Title VIII of the Civil Rights Act of 1968, and Executive Orders 11246 and 11063. These
requirements are briefly described below:
1. Title VI of Civil Rights Act of 1968 Nondiscrimination in any programs or activities receiving
Federal financial assistance.
2. Section 109 of Title I — Housing and Community Development Act of 1974 Nondiscrimination
in any program or activity subject to the provisions of this title. No person in the United States
shall on the ground of race, color, national origin, or sex, be excluded from participation in, be
denied the benefits of, or be subjected to discrimination under any program or activity funded in
whole or part under this Title. Any prohibition against discrimination on the basis of age under
the Age Discrimination Act of 1975 or with respect to an otherwise qualified handicapped
individual as provided in Section 504 of the Rehabilitation Act of 1973 shall also apply to any
such program or activity.
3. Title VIII of the Civil Rights Act of 1968, as amended. Prohibition against discrimination
based on sex.
4. The Fair Housing Law Provides protection against the following acts, if they are based on
disability, race, color, religion, sex, national origin, or family status:
• Refusing to sell or rent to, deal or negotiate with any person Discriminating in terms or
conditions for buying or renting Housing
• Discriminating by advertising that housing is available only to persons of a certain family
status, race, color, religion, sex, or national origin
• Denying that housing is available for inspection, sell or rent when it really is available
• "Blockbusting" - For profit, persuading owners to sell or rent housing by telling them that
minority groups are moving into the neighborhood
• Denying to anyone the use of or participation in any real estate services, such as
brokers' organizations, multiple listing services or other facilities related to the selling or
renting of housing
• Denying or making different terms or conditions for home loans by commercial lenders,
such as banks, savings and loan associations and insurance companies
Page 28 of 41
5. Executive Order 11063 - Equal Opportunity in Housing, as amended by Executive Order
12259 — All departments and agencies are directed to take all action necessary and appropriate
to prevent discrimination in housing and related facilities owned or operated by the Federal
Government or provided with Federal financial assistance and in the lending practices with
respect to residential property and related facilities (including land to be developed for
residential use) of lending institutions, insofar as such practices relate to loans insured or
guaranteed by the Federal Government.
6. Executive Order 11246 — Equal Employment Opportunity, as amended by Executive Order
11375, Part II - Employment under Federal contracts. Non-discrimination in employment by
government contractors and subcontractors. Part 111 - Federally assisted construction contracts.
Non-discrimination in employment under federally assisted construction contracts. Parts 11 and
III are administered by the Department of Labor.
7. Section 3 of the Housing and Development Act of 1968, as amended and as implemented by
HUD regulations at 24 CFR Part 135 Section 3 provides that to the greatest extent feasible,
training and employment opportunities shall be made available to lower Income residents of
project areas and that contracts be awarded to small businesses located within the project area
or owned in substantial part by project area residents.
SECTION 504 REQUIREMENTS
Local government recipients and subrecipients must comply with Section 504 of the
Rehabilitation Act of 1973, as amended. This requirement is similar to the "Americans with
Disability Act" (ADA) which is also applicable. HUD published implementation regulations (24
CFR Part 8) as a final rule on June 2, 1988. The general requirement is that no otherwise
qualified individual with a disability (physical or mental) shall, because a recipient's facilities are
inaccessible to or unusable by individuals with disabilities, be excluded from participation in,
denied benefits, or otherwise be subjected to discrimination under any program or activity that
receives NSP assistance. The definition of disability includes physical and mental factors and
also includes those who may be regarded as handicapped (such as the spouse or children of a
person with AIDS). Both building accessibility and employment practices are covered by Section
504.
AFFIRMATIVELY FURTHERING FAIR HOUSING
Any Subrecipient must certify that it will affirmatively further fair housing, mandated under 24
CFR 570.602.
SECTION 3 OF THE HOUSING AND URBAN DEVELOPMENT ACT OF 1968
As amended, provides that, to the greatest extent feasible, opportunities for training and
employment shall be given to recipients of public housing and lower-income residents of the unit
of local government or the metropolitan area (or non -metropolitan county) in which the project is
located. Contract work in connection with such projects shall be awarded to business concerns
which are owned in substantial part by persons residing in the same metropolitan area (or
nonmetropolitan county) as the project, employ Section 3 residents in full-time positions, or
subcontract with businesses which provide economic opportunities to lower Income persons.
Section 3 Regulations 24 CFR 135.
§ 135.38 Section 3 clause.
Page 29 of 41
All section 3 covered contracts shall include the following clause (referred to as the section 3
clause):
A. The work to be performed under this contract is subject to the requirements of section 3 of
the Housing and Urban Development Act of 1968, as amended, 12 U.S.C. 1701 u (section 3).
The purpose of section 3 is to ensure that employment and other economic opportunities
generated by HUD assistance or HUD-assisted projects covered by section 3, shall, to the
greatest extent feasible, be directed to low- and very low-income persons, particularly persons
who are recipients of HUD assistance for housing.
B. The parties to this contract agree to comply with HUD"s regulations in 24 CFR part 135,
which implement section 3. As evidenced by their execution of this contract, the parties to this
contract certify that they are under no contractual or other impediment that would prevent them
from complying with the part 135 regulations.
C. The contractor agrees to send to each labor organization or representative of workers with
which the contractor has a collective bargaining agreement or other understanding, if any, a
notice advising the labor organization or workers" representative of the contractor's
commitments under this section 3 clause, and will post copies of the notice in conspicuous
places at the work site where both employees and applicants for training and employment
positions can see the notice. The notice shall describe the section 3 preference, shall set forth
minimum number and job titles subject to hire, availability of apprenticeship and training
positions, the qualifications for each; and the name and location of the person(s) taking
applications for each of the positions; and the anticipated date the work shall begin.
D. The contractor agrees to include this section 3 clause in every subcontract subject to
compliance with regulations in 24 CFR part 135, and agrees to take appropriate action, as
provided in an applicable provision of the subcontract or In this section 3 clause, upon a finding
that the subcontractor is in violation of the regulations in 24 GFR part 135. The contractor will
not subcontract with any subcontractor where the contractor has notice or knowledge that the
subcontractor has been found in violation of the regulations in 24 CFR part 135.
E. The contractor will certify that any vacant employment positions, including training positions,
that are filled (1) after the contractor is selected but before the contract is executed, and (2) with
persons other than those to whom the regulations of 24 CFR part 135 require employment
opportunities to be directed, were not filled to circumvent the contractor's obligations under 24
CFR part 135.
F. Noncompliance with HUD's regulations in 24 CFR part 135 may result in sanctions,
termination of this contract for default, and debarment or suspension from future HUD assisted
contracts.
G. With respect to work performed in connection with section 3 covered Indian housing
assistance, section 7(b) of the Indian Self-Determination and Education Assistance Act (25
U.S.C. 450e) also applies to the work to be performed under this contract. Section 7(b) requires
that to the greatest extent feasible (i) preference and opportunities for training and employment
shall be given to Indians, and (ii) preference in the award of contracts and subcontracts shall be
given to Indian organizations and Indian-owned Economic Enterprises. Parties to this contract
that are subject to the provisions of section 3 and section 7(b) agree to comply with section 3 to
the maximum extent feasible, but not in derogation of compliance with section7(b).
Page 30 of 41
Pursuant to 24 CFR 24, all NSP grantees are required to verify that any/all persons, contractors,
consultants, businesses, sub-recipients, etc. that are conducting business with the grantee,
including any city/county or the grantee itself, are not presently debarred, suspended, proposed
for debarment, declared ineligible, or voluntarily excluded from participation in the covered
transaction or in any proposal submitted in connection with the covered transaction. Verification
will be checked through the Excluded Parties Listing System (at website: www.epls.gov).
Page 31 of 41
EXHIBIT A-5. Reporting
REPORTING SCHEDULE
The Developer shall submit quarterly reports to Grantee based on the following schedule.
Reports shall be submitted according to this schedule as long as this Agreement is in force:
Activity Reporting Period
Report Due Date
October 15'— December 31"
Janua 10
Janua 31 s —March 3181Aril
10
A ril 15 —June 30
J61Y 10
July 1 s — September 30
October 10
NSP -1 DEVELOPER AGREEMENT
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
Date Submitted:
Activity Reporting Period:
Contact Person:
Telephone:
Email:
GENERAL
1. Activity Status or Milestones — describe any significant actions taken or outcomes
achieved during this reporting period.
2. Future Actions — what significant actions or outcomes are expected during the next
reporting period?
3. Obstacles — describe any potential obstacles, challenges, or issues that may cause
delay.
Page 32 of 41
ACTIVITY STATUS
Complete the following information bv entering the appropriate numbers for this reporting period
No. Active Projects
No. Properties Demolished
No. Properties Sold
TOTAL
HOUSEHOLD INFORMATION
Complete these tables for those properties sold during this reporting period.
No. Extremely -Low Income Households (0-30% AMI)
No. Very-Low_lncome Households (31-50% AMI)
No, Low-income Households (51-80% AMI)
No, Moderate -income Households (81-120% AMI)
No. Female Head of Households
RACE AND ETHNICITY BENEFICIARIES
White
Black or African American
Asian
American Indian or Alaskan Native
Native Hawaiian or Other Pacific Islander
American Indian/Alaska Native and White
Asian and White
Black/African American and White
American Indian/Alaskan Native and Black/African American
Other Multi -Racial
TOTAL
Page 33 of 41
EXHIBIT A-6. Monitoring
HOMEBUYER(S) NAME:
PROPERTY ADDRESS:
DEVELOPER shall submit the following completed form upon final sale of each property
associated with this Agreement.
SECTION A: PARTICIPANT ELIGIBILITY
il
2.
3.
4
Did the Developer correctly apply income inclusions and exclusions for the
El []
chosen income definition and was the calculation performed correctly?
Yes No N/A
Describe Basis for Conclusion:
Yes No N/A
Describe Basis for Conclusion:
Was household income supported with source documentation?
0 D El
median income (or less than or equal to 50% if the unit was designated for
Yes No N/A
Describe Basis for Conclusion:
Was the family's annual income less than or equal to 120% of the area
El El F]
median income (or less than or equal to 50% if the unit was designated for
he Low Income set-aside)?
Yes No N/A
Describe Basis for Conclusion:
Does the file document that the homebuyer received and completed at leas
eight hours of homebuyer counseling from a HUD -approved housing
counseling agency before purchase?
Yes No N/A
Describe Basis for Conclusion:
Page 34 of 41
5.
M
Does the written agreement with the homebuyer specify that the buyer mus E ❑
use the property as a principal residence throughout the period of
affordability? Yes No N/A
for Conclusion:
; the written agreement specify remedies or actions the Grantee must 0 El El
if the principal residence requirement is not met for the affordability
Yes No N/A
be Basis for Conclusion:
SECTION B: AFFORDABILITY PROVISIONS
7
ME
M
Does the written agreement with the homebuyer include the required El El R
recapture or resale provisions, as described in the Developer Agreement?
Yes No N/A
Describe Basis for Conclusion:
Was the correct period of affordability established for the project, based E R 0
upon the total amount of NSP assistance provided to the homebuyer if
under a resale provision or the direct subsidy provided with NSP funds, if Yes No N/A
under a recapture provision?
Describe Basis for Conclusion:
Were legal documents recorded: deed restriction or covenant running with E 0
he land if the property is under resale provisions, or note/deed of trust and
mortgage for recapture provisions? Yes No N/A
Describe Basis for Conclusion:
Page 35 of 41
SECTION C: PROPERTY STANDARDS
11.
If the project was constructed before 1978, did the Developer comply with
lead -safe housing requirements at 24 CFR Part 35?
scribe Basis for Conclusion:
the project involved rehabilitation or new construction of a unit, does the
ial inspection confirm that the property met all applicable property
andards at completion?
ribe Basis for Conclusion:
Prepared By:
Telephone:
Email:
Page 36 of 41
EJ ❑ ❑
(es No N/A
R ❑ ❑
(es No N/A
EXHIBIT A-7. Income Certification
Neighborhood Stabilization Program 1
Habitat for Humanity of Collier County, Inc.
INSTRUCTIONS
Submit completed form, including appropriate supporting documentation, to Grantee to obtain
approval prior to the sale of a property associated with this Agreement to an eligible person or
household.
Effective Date:
A. Household Information
Member Names — All Household Members Relationship Age
1
2
3
4
5
6
7
8 1.
B. Assets: All Household Members, Including Minors
Income
Member Asset Description Cash Value from
Assets
1
2
3
4
5
6
7
8
Total Cash Value of Assets 13(a)
Total Income from Assets B(b)
If line 13(a) is greater than $5,000, multiply that amount by the rate specified
by HUD (applicable rate 2.0%) and enter results in B(c), otherwise leave
blank. 13(c)
Page 37 of 41
C. Anticipated Annual Income: includes Unearned Income and Support Paid on
Behalf of Minors
Member
Wages t Benefits / Public Other
Salaries Pensions Assistance Income
(include tips,
commissions, Asset
bonuses, and Income
overtime
1
(Enter the
2
greater of
box B(b)or
3
box B(c),
above, in
4
g
box C(e)
below)
6
7
8
(a) (b) (c) (d) (e)
Totals
Enter total of items C(a) through C(e).
This amount is the Annual Anticipated Household Income.
D. Recipient Statement: The information on this form is to be used to determine maximum
income for eligibility. I/we have provided, for each person set forth in Item A, acceptable
verification of current and anticipated annual income. I/we certify that the statements are
true and complete to the best of my/our knowledge and belief and are given under
penalty of perjury.
WARNING: Florida Statutes 817 provides that willful false statements or misrepresentations concerning income and
assets or liabilities relating to financial condition is a misdemeanor of the first degree and is punishable by fines and
imprisonment provided under S. 775.082 and 775.083.
Signature of Head of Household
Signature of Spouse or Co -Head of Household
Date
Date
Adult Household Member (if applicable) Date
Adult Household Member (if applicable) Date
Page 38 of 41
E. NSP Grantee Statement: Based on the representations herein, the family or
individual(s) named in Item A of this Income Certification is/are eligible under the
provisions of the NSP. The family or individual(s) constitute(s) a:
Very -Low Income (VLI) Household means and individual or family whose
annual income does not exceed 50 percent of the area median income as
determined by the U.S. Department of Housing and Urban Development with
adjustments for household size.
(Maximum Income Limit $ }.
Low -Income (LI) Household means and individual or family whose annual
income does not exceed 80 percent of the area median income as determined by
the U.S. Department of Housing and Urban Development with adjustments for
household size.
(Maximum Income Limit $ }.
Moderate -Income (MOD) Household means and Individual or family whose
annual income does not exceed 120 percent of the area median income as
determined by the U.S. Department of Housing and Urban Development with
adjustments for household size.
(Maximum Income Limit $ }.
Based upon the (year) income limits for the Naples -Marco Island Metropolitan
Statistical Area (MSA) of Collier County, Florida.
Signature of the NSP Administrator or His/Her Designated Representative:
Signature
Printed Name
F. Household Data
Date
Title
Number of Persons
By Race / Ethnicity
By A e
White
Black
Hispanic
Asian
American
Indian
Other
0-25
26-40
41-61
62+
Special
Target 1 Special Needs
Check all that apply
Farm Worker
Developmentally
Homeless
Elderly
Other
Disabled
NOTE: Information concerning the rate or ethnicity of the occupants is being gathered for statistical use only. No
occupant is required to give such information he or she desires to do so, and refusal to give such information will not
affect any right he or she has an occupant.
Page 39 of 41
EXHIBIT A-8. Quarterly Performance Report Data
GENERAL
Grantee is required to submit to HUD, through the Disaster Recovery Grant Reporting System
("DRGR") Quarterly Performance Reports ("QPR"). To facilitate in the preparation of such
reports, Developer shall submit the information contained herein within ten (10) days of the end
of each calendar quarter.
1. OVERALL PROGRESS NARRATIVE
Describe overall progress made in operating the NSP.
2. FINANCIAL DATA
Provide (a) number of properties acquired, (b) program funds expended, and (c)
program funds obligated.
3. ACTIVITY PROGRESS NARRATIVE
Described progress made within the following three (3) activities: (a) acquisition,
rehabilitation, resale LMMI, (b) acquisition rehabilitation, resale LH25, and (c) land bank.
4. PROPERTY DATA
Provide the address of each property where funds were expended or obligated this
reporting period.
5. DEMOGRAPHIC DATA
Provide the following data for each household assisted this reporting period: (a) race, (b)
Hispanic/Latino (yes/no), (c) female head of household (yes/no), and (d) income level.
Page 40 of 41
EXHIBIT B. Budget
GENERAL
Developer will be provided ownership in forty-two (42) properties acquired by the Grantee for
the purpose of rehabilitation or redevelopment for disposition to NSP -eligible persons or
families.
Grantee will not provide Developer any NSP -1 funding to support the activities described in this
Agreement. Therefore, there is no activity budget associated with this Agreement.
Grantee shall pay Developer a Five Thousand Five Hundred and 00/100 Dollars ($5,500)
developer fee for each of the forty-two (42) properties associated with this Agreement. The
maximum combined developer fee paid by Grantee to Developer through this Agreement shall
be Two Hundred Thirty One Thousand 00/100 Dollars ($231,000); this amount represents a
cumulative of developer fees paid for each of the properties associated with this Agreement.
Page 41 of 41
AMENDMENT NO.1 TO AGREEMENT FOR THE
NEIGHBORHOOD STABILIZATION PROGRAM 1
CFDA: 14.218
DEVELOPER AGREEMENT BETWEEN
COLLIER COUNTY
AND
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
(NSP -1)
THIS AMENDMENT is made and entered into on this day of L� 2013, by and
between Collier County, a political subdivision of the State of Florida, having its
principal office at 3299 Tamiami Trail East, Naples, Florida 34112 (hereinafter called the
"GRANTEE"), and Habitat for Humanity of Collier County, Inc., a private not-for-profit
corporation, existing under the laws of the State of Florida, having its principal office at
11145 Tamiami Trail East, Naples, Florida 34113 (hereinafter called the "DEVELOPER")
to undertake the Neighborhood Stabilization Program ("NSP -1") as approved by the
Collier County Board of County Commissioners.
RECITALS:
WHEREAS, on April 24, 2012, the parties entered into Neighborhood
Stabilization Program 1, CFD No.12.218, Developer Agreement (Agreement); and
WHEREAS, Exhibit A-1 of the Agreement is a site-specific list of properties to
be transferred from Grantee to Developer; and
WHEREAS, the Parties desire to remove certain properties from Exhibit A-1 of
the Agreement so that those properties may be transferred to a third party or parties, as
allowed under NSP -1.
WHEREAS, Exhibit B of the Agreement is a budget for properties to be
transferred from Grantee to Developer; and
WHEREAS, as a result of a decrease in the number of properties to be
conveyed to Developer, the corresponding budget has been reduced; and
NOW THEREFORE, in consideration of the foregoing Recitals, and other
good and valuable consideration, the Parties agree to modify Exhibit A-1 of the
Agreement as follows:
II, Terms and Conditions of the Funding
A, Funding Amount - NSP -1 Funds in the amount of One Hundred Ninety -Eight
Thousand 00/100 Dollars (198,000) Two Hundred Tjiir� One Theusand7904W
Dollars ($231.000) are obligated for use in compliance with this agreement, as
reflected in the budget in Exhibit B.
EXHIBIT A-1. Legal Descriptions
The following site-specific list of properties is associated with this Agreement and
ownership to such will be transferred from Grantee to Developer following all standard
Collier County closing procedures.
1. Lot 52, Block B, Whispering Pines, a Subdivision of Lots 48 and 49 in Naples
Grove and Truck Company's Little Farms #2, according to the Plat Thereof, as
Recorded in Plat Book 4, Page 17, of the Public Records of Collier County,
Florida. Parcel No. 81732120002 (2842 Barrett Avenue, Naples, FL 34112)
2, Lot 20, in Block 9, of Naples Manor Addition, according to the Plat thereof, as
recorded in Plat Book 3, at Pages 67 and 68, of the Public Records of Collier
County, Florida. Parcel No. 62097920005 (5378 Carlton Street, Naples, FL 34113)
3. Let 5, Bleek 11, Naples Manor Lakes, aeeer-ding te the plat thereef, reeerded
n 1 lir 62261280095 (5318 !"'`ilei 4st Street. Naples FL X 4 13)
4. Let / Bleek 12, Naples Manor Lakes,
aeeerding te the plat thereof-, reeer-ded in.
Nat Book 3, -games -86 d 8;� f the r3 .blie n,,,,,,rds of Collier rte,,., f4y, xl„riaa_
P 1 lel 622613200 1A (5322 G lel..,,at• Street, F 34173)
I'AL'CGTTQp� 4Y-G�'xPGOPO v. -r. vaa..+.s.v,, v.s .... �, ...+1++..�,, :... .++«..(
5- LetA, Bleek 12, N les"-��ar-hakes, aeeEwding-te- the -plat thereof r-eeer-dPlat Beek 3, Pages 86 and 87-, ef the PubRe ReeeT-ds ef Collier Geunty,-
.
Par -eel No. 62261360006 (5326 Gilelffist Street-, Naples, Fb 34113)
6. -Lot 8, Bloc -k 12,- Naples Manor Lakes, aeeer-ding to dw plat her � i r dee
1 LrVreeV1�+N4�.— it
Plat Beek 8615 and
/ Pages / of the Public Recer-dr, of Collier / .
Par -eel No. 62261400095 095 (533 G l„ hrist St,..,e 1 Iaples FL 3 113)
Plat Beek / Pages 86 and 87, , Fierida.
9. Lot 19, Block A, Pine -View Villas, according to the Plat thereof, recorded in Plat
Book 9, Page 49, of the Public Records of Collier County, Florida. Parcel No.
67490760003 (4308 Rose Avenue, Naples, FL 34112)
10, Lot 3, and the East 28 Feet of Lot 4, Block 3, Burdale, according to the Map or Plat
thereof, as recorded in Plat Book 4, Page 2, of the Public Records of Collier
County, Florida. Parcel No. 25081280002 (2522 Linwood Avenue, Naples, FL
34112)
11. Lot 33, Block 188, Golden Gate, Unit 6, according to the Plat thereof, as recorded
in Plat Book 5, Pages 124- 134, of the Public Records of Collier County, Florida.
Parcel No. 36304720005 (2049 55th Terrace SW, Naples, FL 34116)
12. The West 75 Feet of the West 150 Feet of Tract No. 90, Golden Gate Estates, Unit
No. 42, according to the Map or Plat thereof, as recorded in the Plat Book 7, Page
27, of the Public Records of Collier County, Florida. Parcel No. 38847800008 (2860
64th Avenue NE, Naples, FL 34120)
13. The West 75 Feet of the West 150 Feet of Tract 79, Golden Gate Estates, Unit No.
42, according to the Plat thereof, as recorded in Plat Book 7, Page 27, of the Public
Records of Collier County, Florida. Parcel No. 38846560006 (2765 58th Avenue
NE, Naples, FL 34120)
14. The West 75 Feet of Tract 85, Golden Gate Estates, Unit 72, according to the Map
or Plat thereof, as recorded in Plat Book 5, Page 8, Public Records of Collier
County, Florida. Parcel No. 40419040006 (4460 22nd Avenue NE, Naples, FL
34120)
15. Lot 19 and the East Half of Lot 20, Avalon Estates Replat of Unit No. 1, a
Subdivision According to the Map or Plat Thereof, as recorded in Plat Book 4,
Page 65, of the Public Records of Collier County, Florida. Parcel No. 22670520008
(3614 Poplar Way, Naples, FL 34112)
16, Lot 8, Block 59, Golden Gate, Unit 2, according to the Plat Thereof, recorded in
Plat Book 5, Pages 65 through 77, of the Public Records of Collier County,
Florida. Parcel No. 35774280008 (2197 44th Terrace SW, Naples, FL 34116)
r
r
NNAN
r
r.
H-
.•���•
.tWINK
9. Lot 19, Block A, Pine -View Villas, according to the Plat thereof, recorded in Plat
Book 9, Page 49, of the Public Records of Collier County, Florida. Parcel No.
67490760003 (4308 Rose Avenue, Naples, FL 34112)
10, Lot 3, and the East 28 Feet of Lot 4, Block 3, Burdale, according to the Map or Plat
thereof, as recorded in Plat Book 4, Page 2, of the Public Records of Collier
County, Florida. Parcel No. 25081280002 (2522 Linwood Avenue, Naples, FL
34112)
11. Lot 33, Block 188, Golden Gate, Unit 6, according to the Plat thereof, as recorded
in Plat Book 5, Pages 124- 134, of the Public Records of Collier County, Florida.
Parcel No. 36304720005 (2049 55th Terrace SW, Naples, FL 34116)
12. The West 75 Feet of the West 150 Feet of Tract No. 90, Golden Gate Estates, Unit
No. 42, according to the Map or Plat thereof, as recorded in the Plat Book 7, Page
27, of the Public Records of Collier County, Florida. Parcel No. 38847800008 (2860
64th Avenue NE, Naples, FL 34120)
13. The West 75 Feet of the West 150 Feet of Tract 79, Golden Gate Estates, Unit No.
42, according to the Plat thereof, as recorded in Plat Book 7, Page 27, of the Public
Records of Collier County, Florida. Parcel No. 38846560006 (2765 58th Avenue
NE, Naples, FL 34120)
14. The West 75 Feet of Tract 85, Golden Gate Estates, Unit 72, according to the Map
or Plat thereof, as recorded in Plat Book 5, Page 8, Public Records of Collier
County, Florida. Parcel No. 40419040006 (4460 22nd Avenue NE, Naples, FL
34120)
15. Lot 19 and the East Half of Lot 20, Avalon Estates Replat of Unit No. 1, a
Subdivision According to the Map or Plat Thereof, as recorded in Plat Book 4,
Page 65, of the Public Records of Collier County, Florida. Parcel No. 22670520008
(3614 Poplar Way, Naples, FL 34112)
16, Lot 8, Block 59, Golden Gate, Unit 2, according to the Plat Thereof, recorded in
Plat Book 5, Pages 65 through 77, of the Public Records of Collier County,
Florida. Parcel No. 35774280008 (2197 44th Terrace SW, Naples, FL 34116)
17. The West 75 Feet of the East 180 Feet of Tract 90, Golden Gate Estates, Unit No.
62, according to the Plat thereof, as recorded in PIat Book 5, Page 87, of the Public
Records of Collier County, Florida. Parcel No. 39781520003 (3685 41St Avenue
NE, Naples, FL 34120)
18. The West 75 Feet of the East 180 Feet of Tract 43, Golden Gate Estates, Unit No.
71, According to the Plat thereof, recorded in Plat Book 5, Page 7, of the Public
Records of Collier County, Florida. Parcel No. 40355240009 (3380 20th Avenue
NE, Naples, FL 34120)
19. Lot 21, Block 172, Golden Gate, Unit 5, According to the Plat thereof, as
Recorded in Plat Book 5, Pages 117 through 123, inclusive, of the Public Records
of Collier County, Florida. Parcel No. 36245160009 (1853 51st Terrace SW, Naples,
FL 34116)
20. Lot 17, Block 121, Golden Gate, Unit 4, according to the plat thereof, recorded in
Plat Book 5, Pages 107 to 116, inclusive, of the Public Records of Collier County,
Florida. Parcel No. 36113200004 (4913 22nd Place SW, Naples, FL 34116)
21, Lot 8, Block 4, Naples Manor Lakes, according to the Plat thereof, as recorded in
Plat Book 3, Page 86, of the Public Records of Collier County, Florida. Parcel No.
62252520004 (5230 Gilchrist Street, Naples, FL 34113)
22. Lot 22, Block 185, Golden Gate, Unit 6, according to the Plat thereof, of record in
Plat Book 5, Pages 124 through 134, of the Public Records of Collier County,
Florida. Parcel No. 36300880004 (2180 52nd Terrace SW, Naples, FL 34116)
23, Lot 11, Block 135, Golden Gate, Unit 4, according to the Plat thereof, recorded in
Plat Book 5, Page 112, of the Public Records of Collier County, Florida. Parcel No.
36122520005 (4833 21st Avenue SW, Naples, FL 34116)
24, Lot 23, Block 240, Golden Gate, Unit 7, according to the map or plat thereof, on
file and recorded with the Clerk of the Circuit Court and recorded at Plat Book
5, Page 141, Public Records of Collier County, Florida. Parcel No. 36439240007
(3025 52nd Street SW, Naples, FL 34116)
25. Lot 5, Block 56, Golden Gate, Unit 2, according to the plat thereof, as recorded in
Plat Book 5, Pages 65 through 77, inclusive, of the Public Records of Collier
County, Florida. Parcel No. 35772680008 (4440 191h Avenue SW, Naples, FL
34116)
26. Lot 11, Block 45, Unit 2, Golden Gate,, according to the plat thereof, as recorded
in Plat Book 5, Pages 65 through 77, inclusive, of the Public Records of Collier
County, Florida. Parcel No. 35764920006 (4300 17th Avenue SW, Naples, FL
34116)
27. Lot 24, Block 167, Golden Gate, Unit No. 5, according to the plat thereof, as
recorded in Plat Book 5, Pages 117 through 123, of the Public Records of Collier
County, Florida. Parcel No. 36241760005 (2100 51St Terrace SW, Naples, FL 34116)
28, Lot 33, Block 218, Golden Gate, Unit 6 Part 1, according to the plat thereof, as
recorded in Plat Book 9, Pages 1 through 7, inclusive, of the Public Records of
Collier County, Florida. Parcel No. 36383680001 (540121St Place SW, Naples, FL
34116)
29. Lot 11, COL -LEE -CO Gardens, according to the Plat thereof, as recorded in Plat
Book 1, Page 30, of the Public Records of Collier County, Florida. Parcel No.
26830320002 (2972 Gordon Street, Naples, FL 34112)
30. Lot 5, Block D, South Tamiami Heights, according to the Plat thereof, recorded
in Plat Book 3, Page 44, of the Public Records of Collier County, Florida; Parcel
No. 74412200000 (3511 Okeechobee Street, Naples, FL 34112)
31, Lot 10, Block 259, Golden Gate, Unit 7, according to the Plat thereof, recorded in
Plat Book 5, Pages 135 through 146, inclusive, of the Public Records of Collier
County, Florida. Parcel No. 36450840004 (4914 301h Place SW, Naples, FL 34116)
32. Lot 33, Block 5 of Trail Acres, according to the Plat thereof, as recorded in Plat
Book 3, Page(s) 50, of the Public Records of Collier County, Florida. Parcel No.
77214040009 (158 5th Street, Naples, FL 34114)
33, The West Half (West 1/s) of the Northwest Quarter (Northwest 1/4) of the
Northeast Quarter (Northeast 1/4) of the Northwest Quarter (Northwest 1/4) of the
Southwest Quarter (Southwest 1/4) of Section 16, Township 50 South, Range 26
East, Less the Northerly 30 feet thereof, Public Records of Collier County,
Florida. Parcel No. 00418760000 (6067 Pally Avenue, Naples, FL 34112)
34. Lot 2, Block 192, Golden Gate, Unit 6, according to the plat thereof, recorded in
Plat Book 5, Page 130, of the Public Records of Collier County, Florida. Parcel No.
36308560009 (5418 23rd Court SW, Naples, FL 34116)
35. Lot 25, Block 76, Golden Gate, Unit 2, according to the Plat thereof, as recorded
in Plat Book 5, Page(s) 65- 77, of the Public Records of Collier County, Florida.
Parcel No. 35780960008 (2183 41St Street SW, Naples, FL 34116)
36. Lot 58, Hallendale, according to the map or plat thereof, as recorded in Plat Book
4, Page(s) 25, Public Records of Collier County, Florida. Parcel No. 48782160000
(No Site Address)
37. Lot 59, HaIlendale, according to the map or plat thereof, as recorded in Plat Book
4, Page(s) 25, Public Records of Collier County, Florida. Parcel No. 48782200009
(No Site Address)
38, Lot 63, Hallendale, according to the map or plat thereof, as recorded in Plat Book
4, Page(s) 25, Public Records of Collier County, Florida. Parcel No. 48782320002
(No Site Address)
39. Lot 20, Block 6, Avalon Estates, Unit No. 1, according to the Map of the Plat
thereof, as recorded in Plat Book 3, Page 62, of the Public Records of Collier
County, Florida. Parcel No. 22624480107 (No Site Address)
40. Lot 18, Block 6, Avalon Estates, Unit No. 1, according to the Plat thereof, as
recorded in Plat Book 3, Page 62, of the Public Records of Collier County, Florida.
Parcel No. 22624440008 (4561 Dominion Drive, Naples, FL 34112)
41. The West 1/2 of Lot 10 and All of Lots 11 & 12, Block C, Whispering Pines,
According to the Plat Thereof, as Recorded in Plat Book 4, Page 17, Public
Records of Collier County, Florida. Parcel No. 81732480001 (2742 Storter Avenue,
Naples, FL 34112)
42. The East 180 Feet of Tract 91, Golden Gate Estates, Unit No. 42, according to the
Plat thereof, of record in Plat Book 7, Page 27, of the Public Records of Collier
County, Florida. Parcel No. 38848000001 (2883 62nd Avenue NE, Naples, FL
34120)
Exhibit B. Budget
GENERAL
Developer will be provided ownership in thirty-six (36) fefty tive-(42) properties
acquired by the Grantee for the purpose of rehabilitation or redevelopment for
disposition to NSP -eligible persons or families.
BUDGET
Grantee will not provide Developer any NSP1 funding to support the activities
described in this Agreement. Therefore, there is no activity budget associated with this
Agreement.
Grantee shall pay Developer a Five Thousand Five Hundred and 002100 Dollars
($5,500) developer fee for each of the thirty-six (36) forty two (42) properties associated
with this Agreement. The maximum combined developer fee paid by Grantee to
Developer through this Agreement shall be One Hundred Ninety:Eight Thousand
00/100 Dollars (198,000) Twe Hundred ` h t One mt-
this amount represents a cumulative of developer fees paid for each of the properties
associated with this Agreement.
IN WITNESS WHEREOF, the GRANTEE and the DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seals on the date and year
first above written.
ATTEST: BOARD OF COUNJY COMMISSIONERS
Dwight, )w. )rock, Clerk of Courts COL IEAomman
NTj ,FLORIDA
y: :� B
_ g.r y
Da -A, G oriller, Esq.
Ch
Habitat for Humanity of Collier County, Inc.
Ixirst itness - `, A Florida not-for-profit corporation
Ti pe/print witness nameT Nick Kouloheras
' Executive Vice President
Second W.ttness (.
Approved as to form and legal sufficiency:
TType/print witness nameT
Jennifer . White �.`'�
Assistant County Attorney y)Al-1
NEIGHBORHOOD STABILIZATION PROGRAM 1
AMENDMENT NO.2 TO DEVELOPER AGREEMENT BETWEEN COLLIER
COUNTY AND HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
CFDA: 14.218
ON '10%4r%Ar
THIS AMENDMENT, made and entered into on this PN day of TdtJG , to the subject
agreement shall be by and between the parties to the original Agreement, Habitat for Humanity
of Collier County, Inc, EIN 59-1834379, (d/b/a/ Habitat for Humanity), authorized to do
business in the State of Florida, whose business address is 11145 Tamiami Trail E Naples FL
34113, (hereinafter called the "Developer") and Collier County, a political subdivision of the
State of Florida, Collier County, Naples (hereinafter called the "County" or "Grantee").
RE: NEIGHBORHOOD STABILIZATION PROGRAM B -08 -UN -12-0003
In order to continue the services provided for in the original Agreement document referenced
above, the parties agree to amend the Agreement as follows:
Words StruelThrough are deleted; Words Underlined are added:
(Dollar amounts have original underlines)
RECITALS:
WHEREAS, on April 24, 2012, the parties entered into Neighborhood Stabilization
Program 1, CFD No. 12.218, Developer Agreement (Agreement); and
WHEREAS, on February 12, 2013, the parties executed Amendment 1 to the
Neighborhood Stabilization Program 1, CFD No. 12.218 Developer Agreement; and
WHEREAS, Exhibit C is being added to the Developer Agreement -to establish a Land
Bank Plan for the NSPI Developer Agreement in order to enable the NSP1 program to closeout
in compliance with HUD NSP Closeout Guidelines; and
WHEREAS, the Developer Agreement is being amended to include modifications in
order to clarify appraisal language and associated requirements.
NOW THEREFORE, in consideration of the foregoing Recitals, and other good and
valuable consideration, the Parties agree to add Exhibit C to the Agreement as follows:
I. Definitions
2. "Appraisal" means an appraisal which meets the criteria specified in the Uniform
Relocation Assistance and Real Property Acquisition Policies Act ("URA"), as further
defined in 49 CFR 24.103. The NSP Policy Alert entitled "Guidance on NSP Appraisals:
I IPaae 0
Voluntary Acquisitions March 15 2012" requires that acquisition of real property using
federal funds is subject to URA and the additional NSP requirements that an appraisal be
completed or updated within 60 days of a final offer made for the property by a grantee
for the purpose of acquisition Appraisals for the disposition of property are not subject
to the 60 day requirement for acquisitions. The Developer may complete appraisals
beyond the 60 days of final offer as previously defined.
"Current market appraised value" means the value of a property that is established
through an appraisal made in conformity with either: 1) the appraisal requirement of the
URA at 49 CFR 24.103, or 2) the Uniform Standards of Professional Appraisal Practice
("USPAP"), or 3) the appraisal requirements of the Federal Housing Administration
("FHA") or a government sponsored enterprise ("GSE"); and the appraisal must be
completed or updated within 60 days of final offer made for the property by a grantee,
subrecipient, developer, or- indlYidttal-Myer. The 60 day requirement does not apply to
the disposition of a property to a final beneficiary. However, if the anticipated value of
the proposed acquisition is estimated at $25,000 or less, the current market appraised
value of the property may be established by a valuation of the property that is based on a
review of available data and is made by a person the grantee determines is qualified to
make the valuation.
III. Project Requirements
The DEVELOPER agrees to comply with all requirements of the NSP -1 as stated in the NSP
Notice and CDBG regulations, including but not limited to the following:
A. NSP -1 Eligible Use, CDBG National Objective and Eligible Activities — The DEVELOPER
will ensure and document that its NSP -1 activities meet LMMI national objective, eligible
use, allowable cost, and eligible activity requirements of the NSP Notices and CDBG
regulations. The DEVELOPER will ensure that any Land Banking activities will follow the
Land Bank Plan as described in "Exhibit C."
(Signature Page to Follow)
21Page
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
ATTEST:
Dwight E.. Brock, Clerk of Courts
By -C
Dated: �( t
(SE,A)'Atrestas to Chairman's
siqnatttre nn1v.
first Witness
TType/print witness nameT
`- &.- ,4
Second Witness
TType/print witness nameT
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY„FLORIDA
Tom
Habitat for Humanity of Collier County, Inc.
A Florida not-for-profit corporation
By:
Print: c
Title:
Approved as to form and legality:
Jennifer A. B e I p e kio
Assistant County Attorney
40 �Il�
3111age 0
P
EXHIBIT A. Project Description
F. MAXIMUM SALES PRICE
If an abandoned or foreclosed -upon home or residential property is purchased, redeveloped,
or otherwise sold to an individual as a primary residence, then such sale shall be in amount
equal to or less than the cost to acquire and redevelop or rehabilitate such property up to a
decent, safe and habitable condition. The maximum sales price for a property is determined
by aggregating all costs of acquisition, rehabilitation, and redevelopment (including released
activity delivery costs, which generally include, among other things, costs related to the sale
of the property). Note that the maximum sales price may not exceed the current market
value of the unit as established by an appraisal. Note that for disposition neither the County
nor the Developer are required to perform the appraisal in conformance with the NSP Policy
Alert entitled "Guidance on NSP Appraisals: Voluntary Acquisitions March 15, 2012". The
associated guidance is required only when acquiring real property with federal funds. While
the NSPI program does not require an appraisal be done when disposing of property, the
County will require the Developer to perform an appraisal to ensure that the market price is
appropriate, however this disposition appraisal is not subject to the NSP Policy Alert
entitled "Guidance on NSP Appraisals: Voluntary Acquisitions", and may be completed
beyond the time period of 60 dates.
Remainder of Page Left Intentionally Blank
41Pnzr
C�
EXHIBIT C. Land Bank Plan
Neighborhood Stabilization Program
Land Bank Report and Recommendations
Collier County, Florida
October 25, 2013
Report by Gladys Schneider
TDA TA NSP3-018-1
Contents
Overview.....................................................................................................................................................6
CurrentStatus................................................................................................................................................6
Summaryof Recommendations....................................................................................................................7
LandBank Plan Guidelines...........................................................................................................................7
Goal of the Land Bank . .7
NationalObjectives....................................................................................................................................... 8
LandBank Oversight....................................................................................................................................8
Ten Year Limitation on NSP Land Bank Properties. .8
SideLot Disposition......................................................................................................................................9
Future acquisition of properties for the Land Bank.......................................................................................9
Responsibilitiesand Requirements...............................................................................................................9
APPENDIX1..............................................................................................................................................10
APPENDIX 2. . 10
APPENDIX 3 .10
51Page �`
Overview
This resort presents the results of technical assistance provided to Collier County in the
consideration of forming an NSP Land Bank in conjunction with Habitat for Humanity of Collier
County (Habitat). Several discussions were held with County Staff and Habitat representatives,
and both provided documents for the review of land bank policies, developer agreements, and
current land bank inventory. This report provides information on the current situation,
recommendations and proposed land bank plan guidelines. Appendices provide the land bank
inventory in the format that would be included in the Land Bank Plan, a summary of the Collier
County and Habitat for Humanity NSP plans and agreements and a summary of NSP regulatory
citations regardiny, land banks.
Current Status
Collier County authorized the formation and operation of a land bank in its Neighborhood
Stabilization Program (NSP). Habitat currently holds title to vacant residential lots that were
purchased with Collier County NSP1 funds. As the program near completion, the County and
Habitat need to develop specific program policies to carry out the Land Bank strategy that was
authorized in the NSP program. The inventories of properties proposed for the NSP Land Bank
are included in Appendix 1.
Collier County's NSP1 Substantial Amendment provides for the formation and operation of a
land bank (Appendix 2). If enacted, the County would adopt a Land Bank Plan and enter into
agreement with Habitat for Humanityto implement the program. Generallyspeaking, the Land
Bank Plan is designed to carry out the goals of the Neighborhood Stabilization Program (NSP)
with the purpose of removing blight, providing affordable housing, and promoting
redevelopment and revitalization. The Housing and Economic Recovery Act of 2008 (Division
B Title III) is the authorizing legislation for land banks as an eligible use of NSP funding with
certain limitations. Under this legislation, a Land Bank is defined as:
Land bank: A land bank is a governmental or nongovernmental nonprofit entity
established, at least in part, to assemble, temporarily manage, and dispose of vacant land
or the purpose of stabilizing neighborhoods and encouraging re -use or redevelopment of
urban property_ For the purposes of NSP, a land bank will operate in a specific, defined
geographic area. It will purchase properties that have been foreclosed upon and maintain,
assemble, facilitate redevelopment of, market, and dispose of the land -banked properties. If
the land bank is aog� ernntental entity, it may also maintain foreclosed prQperf
y that it
does not own, provided it charges the owner of the property the full cost of the service or
places a lien on the property for the full cost of the service. (see Appendix 3 for fwrther
regulatory background on land banks)
A Land Bank Plan is an NSP requirement if the County intends to close out its NSP grant and
there are NSP assisted properties that have not yet been obligated to an end use that meets one of
the NSP applicable National Objectives. By adopting a Land Bank Plan, the County will be able
to close out its NSP grants if other close-out requirements are met. A Land Bank Plan will
61Page
provide guidance to both parties to ensure that program requirements are met and the proposed
schedule has proper oversight.
Since Habitat already holds title to the NSP properties the NSP1 Substantial Amendment
includes a Land Bank Strategy, there is already a framework for moving forward. Habitat will
administer the Land Bank and report to the County on the activities and disposition of the
properties The Land Bank Plan addresses the NSP 1 properties and defines the specific end use
for their disposition and the national objective that will be met. The Land Bank guidelines can
be included in the Developer Agreements with Habitat or by a separate agreement.
Summary of Recommendations
The County should proceed with a Land Bank Plan and Agreement with Habitat for Humanity to
guide the completion of the 4 remaining_ properties that would be included in the land bank
program The County will not need to revise its NSP1 Substantial Amendment as it included
Eligible Use C Land Bank. The Developer Agreements between Habitat and the County
authorize land banking activities. There are nine NSP1 parcels- all single family residential
lots. Habitat intends to complete the NSP1 homes by the end of 2016. These schedules are
based upon buyer demand and market conditions. The relatively short anticipated timeframe
gives the County some flexibility- it could continue to oversee the eventual completion of the
homes under its current agreements. but would not be able to close out their NSPrg ants.
The adoption of a Land Bank Plan and Agreement with Habitat will enable the County to close
out their NSPrgrants if other requirements are complete. A Land Bank Plan would provide a
more formal understanding of what is to be completed and by when. There would be a basis for
extending the development timeframe if needed, since ten years holding time would be available
from the date of grant closeout. The Collier County program has the benefit of fewer scenarios
than other NSP land banks in that all of the properties are similar and will be obligated for the
development of affordable housing. Side lots, rezoning, re -platting, or other complexities are
absent from this situation resulting in a streamlined approach that will require a minimum of
administrative procedures. There was some mention that some of the lots may turn out to be
wetlands and unbuildable. That possibility is addressed in the guidelines suggested. Finally, the
County has a good working relationship with Habitat and the Land Bank Plan would be an
extension of that relationship to mutual benefit.
Land Bank Plan Guidelines
The following_ guidelines are intended to provide direction for the implementation of the NSP1
program requirements as part of the agreement established between Collier County and Habitat
for Humanity of Collier. It is recommended that these guidelines be included as an amendment
to the effective Developer Agreement between Collier County and Habitat for Humanity.
Goal of the Land Bank
The goal of the Land Bank is to acquire maintain and eventually dispose of NSP assisted
properties within a designated time frame to stabilize neighborhoods in specified geographic
areas in accordance with Neighborhood Stabilization Program rules and regulations.
National Objectives
The acquisition rehabilitation demolition and reconstruction of real property are eligible
activities with NSP funds but the end use must also meet a National Objective. Acquisition and
demolition alone do not meet a national objective. By including an NSP property in a Land
Bank a period of ten years holding is allowed under the program rules before a national
objective must be met. When all NSP grant activities have been completed, and remaining
parcels that have not yet met a national objective are placed in a Land Bank, the grantee may
close out their grant with HUD. This relieves the Grantee from ongoing grants administration
responsibilities even though there may stillbe program income returning; to the Grantee.
The following National Objectives are appropriate for the Collier County NSP Land Bank:
Housing Activities. LMMH. Providing or improving permanent residential structures
that will be serving individuals or households whose gross annual income does not
exceed 120% of the area median income adjusted for family size and as published
annually y HUD. Examples include acquisition, rehabilitation, demolition and
reconstruction of affordable homes.
Area Benefits. LMMH. Activities that benefit all of the residents of a primarily
residential area in which at least 51 % of the residents have incomes at or below 120% of
the area median income. Examples include the donation or sale of a parcel for open
space or conservation.
Land Bank Oversight
The Collier County Department of Housing, Human and Veteran Services will have the
responsibility to monitor the implementation of the Land Bank Plan. Habitat for Humanity of
Collier County, Inc. will be responsible for the maintenance and disposition of the properties.
Ten Year Limitation on NSP Land Bank Properties
All land bank properties must meet a national objective within ten years of the closeout date of
the applicable NSP1 or NSP3 grant. Any properties that have not met a national objective will
immediately be used for CDBG purposes. Since there are no deed reversion clauses, this should
be included in the agreement with Habitat- the lots will revert in tenyet ars ithey have not met a
national obiective.
8111ag,r OA(
Side Lot Disposition
The Collier County Land Bank program does not foresee the sale donation or other transfer of
land bank properties to adjacent property owners.
Future acquisition of properties for the Land Bank
The Collier County Land Bank program does not foresee increasing the inventory of non -NSP
properties in the NSP Land Bank.
Responsibilities and Requirements
1. Habitat is responsible for all maintenance and expenses associated with the stewardship
of the land bank properties.
2. Habitat is responsible for all title and transfer expenses associated with the disposition of
the land bank properties.
3. Habitat will construct homes on buildable properties by the date specified. Purchasers
will be NSP eligible beneficiaries.
4. A minimum of 25% of the NSP funds expended will serve households with incomes at or
below 50% of the area median income, per Developer Agreements.
5. NSP1 funds are used for acquisition only_NSP3 funds can be used for acquisition and
demolition. Reconstruction and all other development, maintenance and transfer costs are
the responsibility of Habitat.
6. Habitat is responsible for reporting to the County on land bank activities and disposition
no less than once annually.
7. Habitat is entitled to a $5,500 per unit developer fee for NSPI homes.
8. The feasibility for eventual development of the properties should be considered to
determine if all properties are suitable for residential construction. If not, the properties
shall be designated as open space or conservation and Habitat may negotiate a transfer to
either a public agency, a nonprofit organization, or may retain title along with full
maintenance responsibilities. In order to meet the Area Benefit rule, (LMMA), the use
must benefit all the residents of a primarily residential neighborhood in which at least
51 % of the residents have incomes at or below 120% of the area median income.
Designation of the non -buildable properties as open space or conservation is an
appropriate area benefit use.
91page I OA(,,
APPENDIX I
Land Bank Inventory
Parcel
NSP Prop -ram
Location/Address
Status
End Use and
Disposition
ID#
NationalOb'ective
Date
NSPI
Hallendale Lot 58
Vacant
Single Family
12/31/2016
lot
Ownership LMMH
NSPI
Hallendale Lot 59
Vacant
Single Family
12/31/2016
lot
Ownership (LMMH)
NSPI
Hallendale Lot 63
Vacant
Single Family
12/31/2016
lot
Ownership (LMMH)
NSPI
2183 41" S.W.
Vacant
Single Family
12/31/2016
lot
Ownership LMMH
NSP 1
5418 23` Court
Vacant
Single Family
12/31/2016
S.W.
lot
Ownership (LMMH)
NSP 1
2742 Storter Ave
Vacant
Single Family
12/31/2016
lot
Ownership (LMMH)
NSPI
Lot 20 Dominion
Vacant
Single Family
1.2/31/2016
Dr.
lot
Ownership (LMMH)
NSPI
288362 nAve N.E.
Vacant
Single Family
12/31/2016
lot
Ownershi (LMMH)
NSPI
4561 Dominion Dr.
Vacant
Single Family
12/31/2016
lot
Ownership (LMMH)
MUM29113
Land Banking Authority
Summary of Collier County NSP Plans and Developer Agreements with Habitat for
Humanity
NSP1 Substantial Amendment, Collier County
The NSPI Substantial Amendment of 2009 includes a strategy for the formation and operation of
a land bank. The plan also includes a strategy for the demolition of land bank. Initial funding
levels for the land bank and demolition activities were $320,000 for acquisition and $12,750 for
demolition.
NSPI Developer Agreement, Collier County and Habitat for Humanity of Collier County
The initial agreement executed 4-24-12 provided $231,000 to Habitat for developer fees for an
estimated 42 homes. The County would purchase the homes and deed them to Habitat. Habitat
was to perform the rehabilitation or reconstruction and sell the units to eligible buyers at their
own expense and receive a developer fee of $5,500 per unit.
The Agreement allows Habitat to perform NSP Eligible Activities A-E, which includes land
bank activities. Other provisions of the Agreement are as follows:
]011'age
CAf
- 25% of the total funding received would be allocated to meeting the low income set-aside
- The developer fee of $5,500 is payable upon sale.
- Habitat may retain all project proceeds
- Long term affordability is the minimum provided by the NSP statute
- The amendment of 2-12-13 reduced the number of units from 42 to 36 along with the
contract amount from $231,000 to $198,000
APPENDIX 3
NSP Statutory and Implementing Citations
NSP Land Bank Background Information (Unified NSP Notice- 75 FR 64322)
NSP Definition of Land Bank
A land bank is a governmental or nongovernmental nonprofit entity_ established, at least in part,
to assemble temporarily- manage and dispose of vacant land for the purpose of stabilizine
neighborhoods and encouraging re -use or redevelopment of urban property. For the purposes of
the NSP a land bank will operate in a specific defined geographic area It will purchase
properties that have been abandoned or foreclosed upon and maintain, assemble, facilitate
redevelopment of market and dispose of the land -banked properties If the land bank is a
governmental entity, it may also maintain abandoned or foreclosed property that it does not own,
provided it charges the owner of the property the full cost of the service or places a lien on the
property for the full cost of the service.
E_likible Uses (Housinz and Economic Recovery Act) and NSP Closeout Notice (Nov. 27.2012
288 FR 70799)
• Establish financing mechanisms for purchase and redevelopment of foreclosed upon
homes and residential properties including such mechanisms as soft -seconds, loan loss
reserves, and shared-eguity loans for low- and moderate -income homebuyers
• Purchase and rehabilitate homes and residential properties that have been abandoned or
foreclosed upon to sell, rent or redevelop such homes and properties
• Establish land banks for homes and residential properties that have been foreclosed
upon
• Demolish blighted structures
• Redevelop demolished or vacant properties
Eligible Activities (CDBC)
The NSP funds used for land banking must correlate with an eligible activity under 24 CFR
570.201(a) Acquisition & (b) Disposition:
A. Acquisition in whole or in part by the recipient, or other public or private nonprofit
entity, by purchase, long-term lease, donation, or otherwise, of real property
(includingair it rights, water rights rights-of-way, easements, and other interests
therein) for any public purpose subiect to the limitations of Sec. 570.207.
II lPage
ON
B. Disposition through sale lease donation or otherwise, of any eal property acquired
with CDBG funds or its retention for public purposes including reasonable costs of
temporarily managing such property or property acquired under urban renewal
provided that the proceeds from any such disposition shall be program income subject
to the requirements set forth in Sec 570.504. (Temporarily managing includes
maintenance assembles facilitating the redevelopment of, and marketing of land
banked properties NSP funds may be used for basic, reasonable maintenance
intended to stabilize theproperty.)
NSP National Obiectives
Each NSP activity must meet a National Objective. NSP national objectives include housing
activities (LMMH) area benefit activities (LMMA) and limited clientele activities (LMMC).
The Closeout Notice added one more- the jobs national objective (LMMJ). Since all of Collier
County's land bank parcels are residential the LMMH and possibly the LMMA would be
4pplicable national objectives.
NSP Closeout Notice -Federal Resister, November 27, 2012 (288 FR 70799)
The Notice describes closeout requirements and additional regulations that apply to grantees
receiving grants under the three rounds of funding under the Neighborhood Stabilization
Program. Land Banks are addressed in several parts of the Closeout Notice.
I A.4.c.(iii) The Closeout Agreement between the grantee and HUD must include "a list of real
property held in an NSP -assisted land bank" and (iv) if the grantee has assisted a land bank, a
plan detailing how the land bank will meet the 10 year maximum holding requirement of Section
II.E.2.d of the Unified NSP Notice and Appendix I, Section E.2.d of the NSP2 NOFA.
IA.2. The Unified NSF Notice was amended to require that grantees report at least annually on
the disposition of land bank properties.
I.A.2. The start date for the ten year maximum holding period will begin the date of the grant
closeout to meet an eligible redevelopment of the property in accordance with NSP requirements.
The grantee is required to obligate or otherwise commit the property for a specific use supporting
neighborhood stabilization.
II.A.2. HUD will provide further direction in reporting and tracking. (subsequent webinars have
provided guidance).
II.A.2(2)(b). Disposition of Land Bank Property. Properties in a land bank will be considered
obligated for redevelopment if the property is:
(1) Owned by a local government or nonprofit entity and identified under a Consolidated
Plan approved by HUD for a CDBG eligible public improvement such as parks, open
space or flood control
(2) Owned by a communis land trust to create affordable housing;_
1211)age
C2(
%
(3) Transferred to and committed for any other use in the annual Action Plan, subject to all
CDBG regulations and no longer part of the NSP program-,,
(4) Designated for affordable housing in accordance with HERA and under development by
an eligible development entity which as control of the site and has expended
predevelopment funds,
(5) Included in a redevelopment plan that has been approved by the local governingbody.
ody.
II.A.2.(2)(c). Any NSP assisted land bank properties remaining in the land bank ten years after
the date of grant closeout shall revert entirely to the CDBG program and must be immediately
used to meet a national obiective or disposed of in accordance with CDBG use of real property
requirements at 24 CFR 570.505.
131Page c f
NEIGHBORHOOD STABILIZATION PROGRAM 1
AMENDMENT N0.3 TO DEVELOPER �Y OF COLLIER COUNTY, NCEMENT BETWEEN R COUNTY AND
HABITAT FOR UMANIT
CFDA: 14.218
THIS AMENDMENT, made and entered into on this _ day of ' - __, � is by and between the
parties to the Agreement between Habitat for Humanity of Collier County, Inc, EIN 59-1834379, (d/b/a/ Habitat
for Humanity), authorized to do business in the State of Florida, whose business address is 11145 Tamiami Trail E
Naples FL 34113, (hereinafter called the "Developer") and Collier County, a political subdivision of the State of
Florida (hereinafter called the "County" or "Grantee"), hereinafter collectively known as the "Parties".
RE: NEIGHBORHOOD STABILIZATION PROGRAM B -08 -UN -12-0003
In order to continue the services provided for in the original Agreement document referenced above, the parties
agree to the following amendments:
Words Strael Through are deleted; Words Underlined are added:
RECITALS:
WHEREAS, on April 24, 2012, the Parties entered into Neighborhood Stabilization Program 1, CFD
No. 12.218, Developer Agreement ("Agreement"); and
WHEREAS, on February 12, 2013, the Parties entered into Amendment 1 to the Agreement; and
WHEREAS, on June 24, 2014, the Parties entered into Amendment 2 to the agreement to provide
expanded guidance on NSP appraisal requirements; and add Exhibit C to establish a Land Bank Plan for the NSP 1
Developer Agreement in order to enable the NSP1 program to closeout in compliance with HUD NSP Closeout
Guidelines; and
WHEREAS, the Parties desire to further amend the Agreement by adding a resale provision to the
Agreement.
NOW THEREFORE, in consideration of the foregoing Recitals, and other good and valuable
consideration, the Parties agree to modify Exhibit A-2 to the Agreement as follows:
EXHIBIT A-2. Affordability Requirements
11Page
GENERAL
HOMEOWNERSHIP: LONG TERM AFFORDABILITY
LONG TERM AVAILABILITY
FOR DEVELOPER SOLD PROPERTIES.
Resale: 24 CFR 92.252(a), (c)(e) and (fl, and 92.254
Resale restrictions shall be implemented for every home buyer property constructed redeveloped, or
rehabilitated in whole or in part with NSP funds in the form of a development subsidy. A
development subsidy consists of the difference between the cost of producing- the unit and the fair
market value of the property. If NSP funds are provided to the property it will be subject to a resale
restriction If the home buyer determines that it no longer intends to use the property as its principal
residence resale restrictions require the homebuyer to sell the propertyto a family -that will use the
property as its principal residence and meets the income limits described in the lien and restrictive
covenant on that property. The house must be affordable to a range of new buyers in the target
affordable range The new buyer must occupy house as principal residence. The remaining resale
restrictions apply to new buyer, for the period of affordability.
The original homebuyer is entitled to a fair return on its investment (as described below) upon the sale
of the property. The fair return will be based on the percentage change in the Consumer Price Index for
All Urban Consumers Owners' Equivalent Rent of Primary Residence category in Table I of the CPI
Detailed Report (the "CPI Index") during the period of the homebuyer's ownership. Accordingly, the
CPI Index during the month the residence was completed the month during which the completion
reports were received by and approved by IHCDA) will be compared to the CPI Index during, the
month the original home buyer sells the residence to determine the percentage of the return. The
homebuyer's investment will include any down payment paid by the homebuyer plus any capital
improvements A capital improvement is any property enhancement that increases the overall value of
the property, adapts it to new uses or extends its life such as: adding windows, insulation, a new drive
way a new furnace a garage bedroom new roof remodeling kitchen etc. Any capital improvement
will be valued based on actual cost as documented by the original homebuyer's receipts. Generally,
replacing worn dated components such as appliances or carpet would not be considered an improvement
that adds value
or adapts it to new uses.
The purchasing family should pay no more than thirty (30%) of its gross family income towards the
principal, interest taxes and insurance for the property on a monthly basis In certain circumstances,
such as a declining housing market where home values are depreciating, the original homebuyer may,
2 1 P a g e
not receive a return on his or her investment because the home sold for less or the same price as the
original purchase price and a loss on investment may constitute a fair return.
Resale Example:
Assumption: NSP funds total
development Total Development
_Costs (TDC $120,000 Sale,price
based on appraisal $90,000 Principle
reduction $10,000
First Purchase mortgage $80,000
Closing cost assistance $1,600
Amount determining compliance
$120,000
Compliance period 15
In the event of a deed in lieu of foreclosure or a foreclosure the lien holder or mortgagee will insure that
that home be sold to a family that will use the property as its principle residence and meets the income
limits described in the lien and restrictive covenant on the property.
(Signature Page to Follow)
3 1 P a g e
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seals on the date and year
first above written.
ATTEST:
Dwight E, <Brock, Clerk of Courts
tv..B�,
tea
SEAL
Attesas to Chaii�an.�:-
Sign
4 1 P a g e
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
By:
Tim Nance, Chairman
Habitat for Humanity of Collier County, Inc.
A Florida not-for-profit corporation
Approved as to form and legality:
S�_� ,P c ck-%'
Jennifer A. Belpedi
Assistant County Attorney
k.\_ k1..
NEIGHBORHOOD STABILIZATION PROGRAM 3
CFDA No. 14.218
DEVELOPER AGREEMENT BETWEEN
COLLIER COUNTY
AND
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
(NSP -3)
0
THIS AGREEMENT, made and entered into on thisa qday of A"-/, , 2012, by and between
Collier County, a political subdivision of the State of Florida, hav! g its principal office at 3299
Tamiami Trail East, Naples, Florida 34112 (hereinafter called the "GRANTEE"), and Habitat for
Humanity of Collier County, Inc., a private not -tor -profit corporation, existing under the laws of
the State of Florida, having its principal office at 11145 Tamiami Trail East, Naples, Florida
34113 (hereinafter called the "DEVELOPER") to undertake the Neighborhood Stabilization
Program ("NSP -3") as approved by the Collier County Board of County Commissioners.
WITNESSETH
WHEREAS, the GRANTEE is the recipient of Neighborhood Stabilization Program
Funds from the U.S. Department of Housing and Urban Development (HUD); and
WHEREAS, the DEVELOPER has submitted a letter of intent, dated December 2, 2011
and incorporated herein by reference, for use of funds for an NSP -3 -eligible PROJECT;
NOW, THEREFORE in consideration of the mutual covenants and obligations herein
contained, including the Attachments, and subject to the terms and conditions hereinafter
stated, the parties hereto understand and agree as follows:
I. Definitions
Unless specifically provided otherwise or the context otherwise requires, when used in this
Agreement:
1. "Abandoned" refers to homes or residential properties that either a) mortgage, tribal
leasehold, or tax payments are at least 90 days delinquent, or b) a code
enforcement inspection has determined that the property is not habitable and the
owner has taken no correction actions within 90 days of notification of the
deficiencies, or c) the property is subject to a court-ordered receivership or nuisance
abatement related to abandonment pursuant to state or local law or otherwise meets
a state definition of an abandoned home or residential property.
2. "Appraisal" means an appraisal which meets the criteria specified in the Uniform
Relocation Assistance and Real Property Acquisition Policies Act ("URA"), as further
defined in 49 CFR 24.103.
3. "Blighted structure" means a structure that exhibits objectively determinable signs of
deterioration sufficient to constitute a threat to human health, safety, and public
welfare as more particularly described in Section 163.340(8), Florida Statutes.
4. "CDBG Act" means the Housing and Community Development Act of 1974, Pub. L.
No. 93-383, as amended. Unless otherwise noted in the Housing and Economic
Page 1 of 43
Recovery Act ("HERA"), as amended, and the alternative requirements in the NSP
Notices, NSP -3 is governed by the CDBG regulations.
5. "Current market appraised value" means the value of a property that is established
through an appraisal made in conformity with either: 1) the appraisal requirement of
the URA at 49 CFR 24.103, or 2) the Uniform Standards of Professional Appraisal
Practice ("USPAP"), or 3) the appraisal requirements of the Federal Housing
Administration ("FHA") or a government sponsored enterprise ("GSE"); and the
appraisal must be completed or updated within 60 days of a final offer made for the
property by a grantee, subrecipient, developer, or individual buyer. However, if the
anticipated value of the proposed acquisition is estimated at $25,000 or less, the
current market appraised value of the property may be established by a valuation of
the property that Is based on a review of available data and is made by a person the
grantee determines is qualified to make the valuation.
6. Eligible Costs means costs for the activities specified in Exhibit A of this
Agreement for which NSP -3 funds are budgeted, provided that such costs (i) are
Incurred in connection with any activity which is eligible under HERA and Section
105A of Title I of the CDBG Act, and (Ii) conform to all NSP -3 requirements.
7. "Environmental Requirements" means the requirements described in 24 CFR Part
58,
8. Foreclosed refers to a home or residential property if any of the following
conditions apply: (a) the property's current delinquency status is at least 60 days
delinquent under the Mortgage Bankers of America delinquency calculation and the
owner has been notified; (b) the property owner is 90 days or more delinquent on
tax payments; (c) under state, local, or tribal law, foreclosure proceedings have
been initiated or completed; or (d) foreclosure proceedings have been completed
and title has been transferred to an intermediary aggregator or servicer that is not
an NSP -3 grantee, contractor, subrecipient, developer, or end user.
9. "HERA" means the Neighborhood Stabilization Program ("NSP -3") found in Title III
of Division B of the Housing and Economic Recovery Act of 2008, as amended.
10. "HUD" means the United States Department of Housing and Urban Development.
11. "Land bank" means a governmental or nongovernmental nonprofit entity
established, at least in part, to assemble, temporarily manage, and dispose of
vacant land for the purpose of stabilizing neighborhoods and encouraging re -use or
redevelopment of urban property. For the purposes of the NSP -3, a land bank will
operate in a specific, defined geographic area. It will purchase properties that have
been abandoned or foreclosed upon and maintain, assemble, facilitate
redevelopment of, market, and dispose of the land -banked properties. If the land
bank is a governmental entity, it may also maintain abandoned or foreclosed
property that it does not own, provided it charges the owner of the property the full
cost of the service or places a lien on the property for the full cost of the service.
12. "LMMI" is a HUD -defined term incorporating households with eligible incomes (at or
below 120% of area median, based on household size and county), including low-,
moderate-, and middle-income, in referring to the national objective of the CDBG
program.
13. "Low -Income Set -Aside" refers to the HERA requirement that not less than 25
percent of the funds NSP -3 funds to the GRANTEE shall be used for the purchase
and redevelopment of abandoned or foreclosed upon homes or residential
properties that will provide permanent housing to individuals or families whose
incomes do not exceed 50 percent of area median income.
14. "NSP Notice" refers to the alternative requirements for NSP -3 issued by HUD in the
Federal Register on October 6, 2008, as modified in the Bridge Notice issued on
June 19, 2009, and the Unified Notice issued on October 19, 2010.
Page 2 of 43
15. "NSP -3 Funds" mean those funds to be provided by the GRANTEE pursuant to the
terms of this Agreement, as specified in Section 11 of this Agreement.
16. "Program Income" means the NSP -3 portion of any proceeds received by the
DEVELOPER and repaid to the GRANTEE.
17. "PROJECT" means the activities described in Exhibit A of this Agreement which are
to be carried out to meet the objectives of the NSP -3.
18. Purchase Discount means the minimum discount percentage from the current
market- appraised value under which a property may be purchased. Under HUD
Notice FR -5255--N-02, the purchase discount for NSP -3 is "at least 1 percent from
the current market -appraised value of the home or property."
19. "Vacant properties" includes both vacant land and properties with vacant structures
on the land.
Il. Terms and Conditions of the Funding
A. Funding Amount — NSP -3 Funds in the amount of Three Million Four Hundred Ninety Five
Thousand Seven Hundred Forty Nine and 001100 Dollars ($3,495.7491 are obligated for
use in compliance with this agreement, as reflected in the budget in Exhibit B.
1. These amounts represent an allocation of the GRANTEE's total NSP -3 funding
contingent upon DEVELOPER performance and not an entitlement to a certain
grant amount, and shall only be disbursed for approved projects and costs.
2. Approved budget — The approved budget is attached to this agreement as Exhibit B.
It is understood and agreed that funds will be used according to the approved
budget. It is understood and agreed that funds will be used according to the
approved budget (Exhibit B). Developer has the authority to reallocate $25,000 per
income category, but shall not expend less than the Low Income Set Aside
allocation of $971,042. Should the Developer determine that the reallocation is
necessary, a prior notification and written approval shall be duly signed by the
Developer and the Director of HHVS. Reallocations above $25,000 between income
categories will require prior Grantee approval.
B. Use of Funds — NSP -3 funds obligated under this agreement may be used as follows:
1. No Commitment or Expenditure Prior to Environmental Clearance — This obligation
of NSP -3 funds is conditional upon satisfactory completion of environmental review
under 24 CFR Part 58 as provided in Section VIII below. Notwithstanding any
provision of this Agreement, the parties hereto agree and acknowledge that this
Agreement does not constitute a commitment of funds or site approval, and that
such commitment of funds or approval may occur only upon satisfactory completion
of environmental review and receipt by GRANTEE of a release of funds from the
U.S. Department of Housing and Urban Development under 24 CFR Part 58. The
parties further agree that the provision of any funds to the project is conditioned on
GRANTEE's determination to proceed with, modify or cancel the project based on
the results of environmental review. Further, the DEVELOPER will not undertake
or commit any funds to physical or choice -limiting actions, including property
acquisition, demolition, movement, rehabilitation, conversion, repair or construction
prior to the environmental clearance, and understands that violation of this provision
may result in the denial of any funds under the agreement.
2. Eligible Activities — Funds may be used for the NSP -3 eligible activities that are
Page 3 of 43
checked below. The number of properties listed is a minimum and is not intended to
provide a limit on the number of properties that may be acquired through this
Agreement:
® Acquisition 27 abandoned or foreclosed single-
family properties
❑ Rehabilitation/reconstruction __.L_acquired abandoned or foreclosed
❑ New construction # vacant properties
3. Eligible Properties — Properties must meet the following conditions to be considered
eligible under this Agreement:
a. Must be located in an NSP -3 Target Area as identified in Exhibit A.
b. Must have no substantial adverse environmental factors as determined by an
environmental review.
C. Must have only one dwelling unit on site; acquisition or two-family or other
mixed owner -rental properties require GRANTEE advance approval in writing
and compliance with NSP -3 rental restrictions.
d. Must otherwise be in suitable locations for marketing and resale to low- and
moderate -income homebuyers.
e. Must be unoccupied and have no personal possessions on site, unless
GRANTEE approves acquisition of an occupied property and stipulates
compliance with relocation requirements in Section VIII.
f. Must be eligible for acquisition under NSP -3 as foreclosed or abandoned or
vacant.
4. Activity Limitations — In implementing projects, DEVELOPER shall undertake only
those activities permitted by this agreement, and comply with all provisions of this
agreement, including the project requirements in Section III, as they may be
modified by HUD. In particular
a. Acquisition —No acquisitions may occur without environmental clearance, and
determination of the applicability of URA provisions.
b. Demolition — Primary structures on properties acquired or contributed may not
be demolished unless they are declared as blighted by GRANTEE. Such
declarations by GRANTEE shall be made in conformance with the definition
contained in Section 163.340(8), Florida Statutes.
C. Cost Limits — All uses of funds are subject to the approval of the GRANTEE.
1. Cost Limits on Individual Units — The cost and assistance limits checked below
apply to every unit assisted with NSP -3 funds under this agreement:
® Developer fee allowed per dwelling unit M000
® Maximum NSP reimbursement per dwelling unit $150,000
D. Deadlines — Timely completion of the work specified in this agreement is an integral and
essential part of performance. The NSP -3 funds are subject to Federal deadlines and
failure to comply could result in the loss of the Federal funds. By the acceptance and
Page 4 of 43
execution of this agreement, it is understood and agreed by the DEVELOPER that the
PROJECT will be completed as expeditiously as possible and that the DEVELOPER will
make every effort to ensure that the project will proceed and will not be delayed. Failure
to meet these deadlines can result in cancellation of this contract and the revocation of
NSP -3 funds.
1. Project Expenditure Deadlines — All project activities and all expenditures of NSP -3
funds must be completed by March 11, 2014. If checked the additional deadlines
apply to project expenditures:
® 50% of NSP -3 funds expended and 03/11/2013
drawn by
® 100% of NSP -3 funds expended and 03/11/2014
drawn by
2. The DEVELOPER expressly agrees to complete all work required by this agreement
in accordance with the timetable set forth above.
a. If DEVELOPER fails to obligate or expend NSP -3 funds as indicated in this
agreement, GRANTEE in its sole discretion may recapture a portion or all of
the DEVELOPER's total NSP -3 funding allocation.
b. Changes to the timetable may be approved by the GRANTEE, in the event the
DEVELOPER is unable to meet the above deadlines or complete the above
services because of delays resulting from Acts of God, untimely review and
approval by the GRANTEE and other governmental authorities having
jurisdiction over the PROJECT, or other delays that are not caused by the
DEVELOPER, the GRANTEE shall grant a reasonable extension of time for
completion of the WORK. It shall be the responsibility of the DEVELOPER to
notify the GRANTEE promptly in writing whenever a delay is anticipated or
experienced, and to inform the GRANTEE of all facts and details related to the
delay. However, GRANTEE may not provide extensions beyond deadlines
imposed by HUD.
3. Since it is mutually agreed that time is of the essence, the DEVELOPER shall cause
appropriate provisions to be inserted in all contracts or subcontracts relative to the
work tasks required by this agreement, in order to ensure that the PROJECT will be
completed according to the timetable set forth in this agreement.
E. Sale to Buyers — All units acquired under this agreement shall be sold to eligible buyers in
accordance with the provisions of this section.
Eligible Buyers — Eligible homebuyers must be determined to be income -eligible in
compliance with the limits and funding allocations checked below. It is understood and
agreed that funds will be used according to the approved budget (Exhibit B). Developer
has the authority to reallocate $25,000 per income category, but shall not expend less
than the Low Income Set Aside allocation of $971,042. Should the Developer determine
that the reallocation is necessary, a prior notification and written approval shall be duly
signed by the Developer and the Director of HHVS. Reallocations above $25,000
between income categories will require prior Grantee approval.
1.
® Middle Income — 81% to 120% of Area Median $750,000
Income
® Moderate Income — 51 % to 80% of Area Median $1,504,707
Income
Page 5 of 43
Z Low Income — less than 50% of Area Median $971,042
Income
2, Sales Price — Sales prices must be in compliance with the price limits in Section
III.F, and the sales price of each property must be approved by GRANTEE.
3. Income Certification and Documentation — Every purchaser shall be determined to
be eligible according to the requirements at 24 CFR 570.5.
4. Net Proceeds of Sale — Upon sale of an NSP -3 -funded home, DEVELOPER will
retain all net proceeds for future use as approved by GRANTEE. Such future use
must be for an NSP -eligible activity. GRANTEE has explicitly elected to forgo
recapture of any and all net proceeds and to have such net proceeds remain with
DEVELOPER.
III. Project Requirements
The DEVELOPER agrees to comply with all requirements of the NSP -3 as stated in the NSP
Notice and CDBG regulations, including but not limited to the following:
A. NSP -3 Eligible Use, CDBG National Objective and Eligible Activities — The DEVELOPER
will ensure and document that its NSP -3 activities meet LMMI national objective, eligible
use, allowable cost, and eligible activity requirements of the NSP Notices & CDBG
Regulations. The DEVELOPER will ensure that any expenditure of NSP -3 funds will be in
compliance with the requirements, and acknowledges that NSP -3 funds will only be
provided as reimbursement for eligible costs incurred, including actual expenditures or
invoices for work completed.
B. Property Acquisition — If any foreclosed -upon homes or residential properties are to be
acquired with NSP -3 funds, the DEVELOPER will acquire property with NSP -3 funds at a
minimum discount of one percent from fair market value for each residential property.
This requirement applies to foreclosed properties purchased with NSP -3 funds, and the
discount must be taken from the current market appraised value as described In the NSP -
3 NOFA.
1. Eligible properties — HERA and NSP -3 limits the properties that are eligible for
assistance to certain locations and types of properties (depending on the Eligible
Use.) Eligible locations are listed in Exhibit A. If the DEVELOPER has proposed
to undertake any activities subject to the NSP -3 Low -Income Set -Aside, these
activities may only be undertaken on foreclosed or abandoned residential property.
2. Prohibition against eminent domain — The DEVELOPER will not undertake any
involuntary acquisition of property with NSP -3 funds without prior written consent of
the GRANTEE and written opinion of counsel that such acquisition is lawful.
3. Appraisal — Appraisals for acquisitions funded with NSP -3 funds are required for all
foreclosed properties. Exceptions to this requirement may be approved by the
GRANTEE.
a. NSP -3 requires appraisals to be performed with respect to the NSP -3 funded
acquisition of foreclosed upon homes and residential properties, even though
they may be considered voluntary under the URA. The GRANTEE further
requires an appraisal for all NSP -3 -assisted acquisitions of property to ensure
cost reasonableness.
b. The URA appraisal requirements of 49 CFR 24.103 must be met. For
Page 6 of 43
C.
L7
E.
acquisitions which meet the applicable voluntary acquisition requirements of
49 CFR 24.101(b), the DEVELOPER must ensure that the owner is informed
in writing of what it believes to be the market value of the property, and that
the DEVELOPER will not acquire the property if negotiations fail to result in a
an amicable agreement (see 49 CFR 24.101(b)(1) & (b)(2)).
C. The appraisal must have been completed within 60 days of the offer made for
the property (an initial offer can be made, subject to the completion of the
appraisal within 60 days of a final offer).
4. Occupied properties — If the PROJECT is occupied at the time of this commitment,
the DEVELOPER will comply with the relocation requirements of 24 CFR 570.606.
5. Purchase Discounts — HERA requires all NSP -3 -assisted acquisitions of foreclosed
property to be at a discount from the current market appraised value of the property,
taking into account its current condition, and such discount shall ensure that the
DEVELOPER is paying below-market value for the home or property. A minimum
discount of 1 percent less than current market appraised value for each property
purchased with NSP -3 funds is required for all acquisitions funded with NSP -3. The
address, appraised value, purchase offer amount, and discount amount of each
foreclosed property purchase must be documented in the DEVELOPER's records.
Demolition — The DEVELOPER may demolish major or convert units from non-residential
uses only with the prior written permission of GRANTEE.
Construction/rehabilitation — For any construction or rehabilitation in this project,
DEVELOPER will comply with the provisions of Section VII. If this project involves the
construction or rehabilitation of properties with 8 or more units, the DEVELOPER shall
comply with the provisions of the Davis -Bacon Act and regulations (29 CFR, Part 5), as
amended. If the building or commonly owned development (e.g. condo or townhouse)
has 8 or more units, Davis Bacon is applicable, even if NSP -3 funds only treat one unit.
Property Standards — The DEVELOPER will carry out all NSP -3 -assisted activities in
accordance with applicable laws, codes, and other requirements relating to housing
safety, quality, and habitability, in order to sell, rent, or redevelop such homes and
properties.
1. Rehabilitation Standards — DEVELOPER will carry out all NSP -3 -assisted
rehabilitation of a foreclosed -upon home or residential property in compliance with
the rehabilitation standards in the GRANTEE's NSP -3 substantial amendment, and
in accordance with applicable laws, codes, and other requirements relating to
housing safety, quality, and habitability.
2. Lead-based paint — The DEVELOPER agrees that any construction or rehabilitation
of residential structures with assistance provided under this Agreement shall be
subject to HUD Lead -Based Paint Regulations at 24 CFR 570.487 or 24 CFR
570.608, and 24 CFR Part 35, Subpart B. Such regulations pertain to all NSP -3 -
assisted housing and require that all owners, prospective owners, and tenants of
properties constructed prior to 1978 be properly notified that such properties may
include lead-based paint. Such notification shall point out the hazards of lead-
based paint and explain the symptoms, treatment and precautions that should be
taken when dealing with lead-based paint poisoning and the advisability and
availability of blood lead level screening for children under seven. The notice
should also point out that if lead-based paint is found on the property, abatement
measures may be undertaken. The regulations further require that, depending on
the amount of Federal funds applied to a property, paint testing, risk assessment,
Page 7 of 43
treatment and/or abatement may be conducted.
3. Accessibility — The DEVELOPER shall work with any homebuying household that
includes a person with disabilities to provide accessibility modifications required
under the policy of reasonable accommodations and reasonable modifications. All
such modifications shall be considered to be eligible NSP -3 costs under this
agreement.
F. Maximum Sales Price — The final sales price shall not exceed the amount permitted by the
NSP -3 requirements listed below:
1. If an abandoned or foreclosed upon home or residential property is to be sold to an
individual as a primary residence, no profit may be earned on such sale.
2. HERA Section 2301(d)(2) directs that the sale of such property shall be in an
amount equal to or less than the cost to acquire and redevelop or rehabilitate such
home or property up to a decent, safe, and habitable condition. Further, the sale
price must be the lesser of the post -development fair market value or the
acquisition/redevelopment cost.
3. The maximum sales price for a property is determined by aggregating all costs of
acquisition, rehabilitation, and redevelopment (including related activity delivery
costs, which generally include, among other things, costs related to the sale of
property).
4. In determining the sales price, the GRANTEE will NOT consider the costs of
boarding up, lawn mowing, maintaining the property in a static condition, or, in the
absence of NSP -3 -assisted rehabilitation or redevelopment, the costs of completing
a sales transaction or other disposition to be redevelopment or rehabilitation costs.
G. Sale and Occupancy — All of the funds made available under this Agreement shall be
used with respect to:
1. Buyer Qualification — All buyers of NSP -3 -assisted units shall be individuals and
families whose incomes do not exceed 120% of area median income (referred to as
"low-, moderate- and middle-income", or LMMI). DEVELOPER shall verify and
document income eligibility of all buyers in compliance with 570.203(a) definition of
"Income."
a. Low -Income Set -Aside (if applicable) — If applicable, the DEVELOPER must
expend at least the amount of set-aside funding identified in Exhibit A of this
Agreement to create permanent housing for households with incomes at or
below 50% of area median. The DEVELOPER may choose to expend more
than the set-aside amount from NSP -3 funds allocated within Eligible Uses A
and B, but within the total NSP -3 award covered by this agreement, and doing
so will not require an amendment to this Agreement.
2. Counseling Requirement — Each NSP -3 -assisted homebuyer is required to complete
at least eight hours of homebuyer counseling from a HUD -approved housing
counseling agency or a counselor approved by the GRANTEE.
3. First Mortgage — DEVELOPER must ensure that homebuyers obtain a mortgage
loan from a lender who agrees to comply with the bank regulators' guidance for non-
traditional mortgages. DEVELOPER is prohibited from permitting homebuyers to
obtain subprime mortgages for whom such mortgages are inappropriate.
4. Affordability Period — All NSP -3 -assisted units must adhere to the affordability
provisions as listed in Exhibit A-1, which is based upon the total amount of NSP -3
Page 8 of 43
funds provided per unit.
a. Affordability periods must be enforced utilizing a mortgage, promissory note
and, where applicable, deed restriction.
b. The Affordability Period is a minimum standard, and DEVELOPER may
propose a longer Affordability Period.
5. NSP -3 Note and Mortgage — For any units that are to be owner -occupied, the
DEVELOPER shall assure that any NOTES and MORTGAGES recorded for NSP -3
buyers shall be in compliance with the GRANTEE's Substantial Amendment to its
Consolidated Plan, in the form prescribed by or acceptable to the GRANTEE.
H. Project Monitoring and Recordkeeping — The DEVELOPER will be monitored by the
GRANTEE for compliance with the NSP -3 requirements and the applicable CDBG
regulations of 24 CFR Part 570. The DEVELOPER will provide reports and access to
project files, including homebuyer files, as requested by the GRANTEE during the
PROJECT and for Five (5) years after completion and closeout of the AGREEMENT as
required under Section IX of this Agreement.
IV. GRANTEE Responsibilities
A. GRANTEE is responsible for the following tasks and deliverables.
B. The GRANTEE shall furnish the DEVELOPER with information regarding requirements for
the project, including any changes in NSP -3 regulations or program limits that affect the
project, including but not limited to income limits.
C. Environmental Review — GRANTEE will complete environmental assessments and provide
clearances for all NSP -3 target areas, as well as approvals of site-specific environmental
reviews prepared by DEVELOPER and delivered to GRANTEE.
D. Inspections — The GRANTEE will conduct progress Inspections of work completed and
review of project files and information to protect its interests as lender and regulatory
authority for the project, and will provide information to the DEVELOPER regarding any
progress inspections or monitoring to assist it in ensuring compliance. The GRANTEE's
review and approval will relate only to overall compliance with the general requirements of
this Agreement and NSP -3 requirements, and all GRANTEE regulations and ordinances.
E. Disbursements — GRANTEE will manage all draws of NSP -3 funds from HUD and
payment of valid and properly documented draw requests from DEVELOPER. The
GRANTEE will disburse funds as provided in Section IV of this Agreement. GRANTEE
will process requests for disbursements of NSP -3 funds, including necessary construction
inspections, in a timely manner. GRANTEE will clearly and promptly describe any
deficiencies identified by GRANTEE that prevent a disbursement or portion of a
disbursement from being approved.
F. Reporting — GRANTEE will report to HUD via the Disaster Recovery Grant Reporting
System (DRGR) system and on www.FederalReporting.gov in a timely manner as required
by HUD.
G. Monitoring — GRANTEE will monitor all program activities of DEVELOPER to assure
compliance with the terms of this Agreement including all NSP -3 requirements.
Page 9 of 43
H. Nothing contained herein shall relieve the DEVELOPER of any responsibility as provided
under this Agreement.
V. Disbursement of Funds
A. Project expenses (excluding developer fee) shall be paid based on vouchers for actual
expenses incurred or paid. All such expenses shall be in conformance to the approved
project budget. It is understood and agreed that funds will be used according to the
approved budget (Exhibit B). Developer has the authority to reallocate $25,000 per
income category, but shall not expend less than the Low Income Set Aside allocation of
$971,042. Should the Developer determine that the reallocation is necessary, a prior
notification and written approval shall be duly signed by the Developer and the Director of
HHVS. Reallocations above $25,000 between income categories will require prior Grantee
approval.
B. Requests for payment must be submitted by the DEVELOPER on forms specified by the
GRANTEE, with adequate and proper documentation of eligible costs incurred in
compliance with NSP -3 and CDBG rules. The DEVELOPER agrees to submit requests
for payment in a timely manner in the form and times directed by the GRANTEE.
C. The GRANTEE will pay to the DEVELOPER funds available under this Agreement based
upon information submitted by the DEVELOPER and consistent with any approved budget
and GRANTEE policy concerning payments. Payments will be made for eligible NSP -3
related expenses actually incurred by the DEVELOPER, and will not exceed actual cash
requirements. In addition, the GRANTEE reserves the right to liquidate funds available
under this contract for costs incurred by the GRANTEE on behalf of the DEVELOPER.
D. Funds will be drawn through the Disaster Recovery Grant Reporting (DRGR) system,
which generally provides access to grant funds within 3 working days of an electronically
submitted request by the GRANTEE. To ensure expeditious implementation of activities,
GRANTEE will draw funds from DRGR and make payment to the DEVELOPER promptly
on receipt of the DEVELOPER's complete and properly submitted requests for payment
for activities under this agreement, if feasible.
E. The NSP -3 funds will be secured by a note and mortgage on the property, which shall be
released upon sale to an eligible buyer.
F. The GRANTEE reserves the right to inspect records and project sites to determine that
reimbursement and compensation requests are reasonable. The GRANTEE also
reserves the right to hold payment until adequate documentation has been provided and
reviewed.
G. The DEVELOPER may submit a final invoice upon completion. Final payment shall be
made after the GRANTEE has determined that all services have been rendered, files and
documentation delivered, and units have been placed in service in full compliance with
NSP -3 regulations, including submission of a completion report and documentation of
eligible occupancy, property standards and long-term use restrictions.
H. The GRANTEE shall pay the DEVELOPER as maximum compensation for the developer
services as provided in the approved Budget in Exhibit B. If multiple projects or buildings
are involved, the developer fee may be pro -rated to each building or project, and the
applicable percentage may be applied to each.
I. The DEVELOPER shall retain any net proceeds of sales, after the payment of all closing
costs and approved developer fee, under this contract, and shall comply with the following
(as checked):
Page 10 of 43
F71 The DEVELOPER may reuse such net proceeds of sale for NSP -3 -eligible
activities..
❑ The DEVELOPER shall return the net proceeds of each sale to the
GRANTEE at each closing.
VI. Repayment of Funds
A. All NSP -3 funds are subject to repayment in the event the PROJECT does not meet the
Project Requirements and Other Requirements as outlined in this Agreement, including
deadlines.
B. It is understood that, upon the completion of the PROJECT, any NSP -3 funds obligated
but not expended under this agreement will revert to the GRANTEE.
VII. Contracting, Labor & Hiring Provisions
During the performance of this contract, the DEVELOPER agrees as follows:
A. The DEVELOPER will not discriminate against any employee or applicant for employment
because of race, color, religion, sex, or national origin(s). The DEVELOPER will take
affirmative action to ensure the applicants are employed, and that employees are treated
during employment, without regard to their race, color, religion, sex or national origin(s).
Such action shall include, but not be limited to, the following: employment, upgrading,
demotion, or transfer, recruitment or recruitment advertising; layoff or termination; rates of
pay or other forms of compensation; and selection for training, including apprenticeship.
The DEVELOPER agrees to post in conspicuous places, available to employees and
applicants for employment, notices to be provided by the contracting officer of the
GRANTEE setting forth the provisions of this nondiscrimination clause.
B. The DEVELOPER will, in all solicitations or advertisements for employees placed by or on
behalf of the DEVELOPER, state that all qualified applicants will receive consideration for
employment without regard to race, color, religion, sex, or national origin.
C. The DEVELOPER will comply with all provisions of Executive Order 11246 of September
24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor.
D. The DEVELOPER will furnish all information and reports required by Executive Order
11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary
of Labor, or pursuant thereto, and will permit access to its books, records, and accounts
by the GRANTEE and the Secretary of Labor for purposes of investigation to ascertain
compliance with such rules, regulations, and order.
1. In the event the DEVELOPER is found to be in noncompliance with the
nondiscrimination clauses of this contract or with any of such rules, regulations or
orders, this contract may be canceled, terminated or suspended in whole or in part
and the DEVELOPER may be declared ineligible for further Government contracts
in accordance with procedures authorized in Executive Order 11246 of September
24, 1965, and such other sanctions may be imposed and remedies invoked as
provided in Executive Order 11246 of September 24, 1965 or by rule, regulations, or
order of the Secretary of Labor or as otherwise provided by law.
Page 11 of 43
E. The DEVELOPER will include the provisions of this Section in every subcontract or
purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor
issued pursuant to Section 204 of Executive Order 11246 of September 24, 1965, so that
such provisions will be binding upon each subcontractor or vendor. The DEVELOPER will
take such action with respect to any subcontract or purchase order as the GRANTEE may
direct as a means of enforcing such provisions, including sanctions for noncompliance;
provided, however, that in the event the DEVELOPER becomes involved in, or is
threatened with litigation with a subcontractor or vendor as a result of such direction by
the GRANTEE, the DEVELOPER may request the United States to enter into such
litigation to protect the interest of the United States.
F. The DEVELOPER agrees to comply with the non-discrimination in employment and
contracting opportunities laws, regulations, and executive orders referenced in 24 CFR
570.607, as revised by Executive Order 13279. The applicable non-discrimination
provisions in Section 109 of the HCDA are still applicable.
G. The DEVELOPER agrees to comply with the requirements of the Secretary of Labor in
accordance with the Davis -Bacon Act, as amended, the provisions of Contract Work
Hours and Safety Standards Act (40 U.S.C. 327 et seq.) and all other applicable Federal,
state and local laws and regulations pertaining to labor standards insofar as those acts
apply to the performance of this Agreement.
H. The DEVELOPER agrees to comply with the Copeland Anti -Kick Back Act (18 U.S.C. 874
et seq.) and its implementing regulations of the U.S. Department of Labor at 29 CFR Part
5. The DEVELOPER shall maintain documentation that demonstrates compliance with
hour and wage requirements of this part. Such documentation shall be made available to
the GRANTEE for review upon request.
The DEVELOPER will use its best efforts to afford small businesses, minority business
enterprises, and women's business enterprises the maximum practicable opportunity to
participate in the performance of this contract. As used in this contract, the terms "small
business" means a business that meets the criteria set forth in Section 3(a) of the Small
Business Act, as amended (15 U.S.C. 632), and "minority and women's business
enterprise means a business at least fifty-one (51) percent owned and controlled by
minority group developers or women. The DEVELOPER may rely on written
representations by businesses regarding their status as minority and women -owned
business enterprises in lieu of an independent investigation.
The DEVELOPER agrees that, except with respect to the rehabilitation or construction of
residential property containing less than eight (8) units, all contractors engaged under
contracts in excess of $2,000.00 for construction, renovation or repair work financed in
whole or in part with assistance provided under this contract, shall comply with Federal
requirements adopted by the GRANTEE pertaining to such contracts and with the
applicable requirements of the regulations of the Department of Labor, under 29 CFR
Parts 1, 3, 5 and 7 governing the payment of wages and ratio of apprentices and trainees
to journey workers; provided that, if wage rates higher than those required under the
regulations are imposed by state or local law, nothing hereunder is intended to relieve the
DEVELOPER of its obligation, if any, to require payment of the higher wage. The
DEVELOPER shall cause or require to be inserted in full, in all such contracts subject to
such regulations, provisions meeting the requirements of this paragraph. The
DEVELOPER shall comply with the provisions of the Copeland Anti -Kick -Back Act (18
U.S.C. 874) as supplemented in Labor Regulations (29 CFR Part 3), as amended.
Page 12 of 43
K. Compliance with the provisions of Section 3 of the Housing and Urban Development Act
of 1968, as amended, and as implemented by the regulations set forth in 24 CFR 135,
and all applicable rules and orders issued hereunder prior to the execution of this contract,
shall be a condition of the Federal financial assistance provided under this contract and
binding upon the GRANTEE, the DEVELOPER and any of the DEVELOPER's contractors
and subcontractors. The DEVELOPER certifies and agrees that no contractual or other
disability exists that would prevent compliance with these requirements.
1. The DEVELOPER further agrees to comply with these Section 3 requirements and
to include the following language in all subcontracts executed under this Agreement:
"The work to be performed under this Agreement is a project assisted under a
program providing direct Federal financial assistance from HUD and is subject to the
requirements of Section 3 of the Housing and Urban Development Act of 1968, as
amended (12 U.S.C. 1701). Section 3 requires that to the greatest extent feasible
opportunities for training and employment be given to low- and very low-income
residents of the project area, and that contracts for work in connection with the
project be awarded to business concerns that provide economic opportunities for
low- and very low-income persons residing in the metropolitan area in which the
project is located."
2. The DEVELOPER further agrees to ensure that opportunities for training and
employment arising in connection with a housing rehabilitation (including reduction
and abatement of lead-based paint hazards), housing construction, or other public
construction project are given to low- and very low-income persons residing within
the metropolitan area in which the NSP -3 -funded project is located; where feasible,
priority should be given to low- and very low-income persons within the service area
of the project or the neighborhood in which the project is located, and to low- and
very low-income participants in other HUD programs; and award contracts for work
undertaken in connection with a housing rehabilitation (including reduction and
abatement of lead-based paint hazards), housing construction, or other public
construction project to business concerns that provide economic opportunities for
low- and very low-income persons residing within the metropolitan area in which the
NSP -3 -funded project is located; where feasible, priority should be given to business
concerns that provide economic opportunities to low- and very low-income residents
within the service area or the neighborhood in which the project is located, and to
low- and very low-income participants in other HUD programs.
3. The DEVELOPER further warrants and agrees to include or cause to be included
the criteria and requirements of this Section in every non-exempt subcontract in
excess of $100,000. The DEVELOPER also agrees to take such action as the
federal, state or local government may direct to enforce aforesaid provisions.
Vill. Compliance with Other Federal, State & Local Laws
A. The DEVELOPER covenants and warrants that it will comply with all applicable laws,
ordinances, codes, rules and regulations of the state local and federal governments, and
all amendments thereto.
B. Environmental review — All NSP -3 assistance is subject to the National Environmental
Policy Act of 1969 and related federal environmental authorities and regulations at 24
CFR Part 58.
1. No NSP -3 project funds will be disbursed, and no costs can be incurred, until the
Page 13 of 43
GRANTEE has conducted an environmental review of the proposed project site as
required under 24 CFR Part 58. The environmental review may result in a decision
to proceed with, modify or cancel the project. Notwithstanding any provision of this
Agreement, the parties hereto agree and acknowledge that this Agreement does not
constitute a commitment of funds or site approval, and that such commitment of
funds or approval may occur only upon satisfactory completion of environmental
review and receipt by the GRANTEE of a release of funds from the U.S. Department
of Housing and Urban Development under 24 CFR Part 58.
2. Further, the DEVELOPER will not undertake or commit any funds to physical or
choice -limiting actions, including property acquisition, demolition, movement,
rehabilitation, conversion, repair or construction prior to the environmental
clearance, and must indicate that the violation of this provision may result in the
denial of any funds under the agreement.
3. A copy of the Environmental Review Record shall be maintained by both the
DEVELOPER and the GRANTEE.
C. Flood Disaster Protection — In accordance with the requirements of the Flood Disaster
Protection Act of 1973 (42 U.S.C. 4001), the DEVELOPER shall assure that for activities
located in an area identified by the Federal Emergency Management Agency (FEMA) as
having special flood hazards, flood insurance under the National Flood Insurance
Program is obtained and maintained as a condition of financial assistance for acquisition
or construction purposes (including rehabilitation.)
D. Historic Preservation — The DEVELOPER agrees to comply with the Historic Preservation
requirements set forth in the National Historic Preservation Act of 1966, as amended (16
U.S.C. 470) and the procedures set forth in 36 CFR Part 800, Advisory Council on Historic
Preservation Procedures for Protection of Historic Properties, insofar as they apply to the
performance of this agreement.
E. Relocation — The DEVELOPER agrees to comply with the Uniform Relocation Assistance
and Real Property Acquisition Policies Act of 1970, as amended (URA), and implementing
regulations at 49 CFR Part 24; 24 CFR Part 42 — Displacement, Relocation Assistance
and Real Property Acquisition for HUD and HUD Assisted Programs; and 24 CFR
570.606 — Displacement, relocation acquisition, and replacement of housing, as may be
amended by the NSP Notice. The DEVELOPER also agrees to comply with applicable
GRANTEE or local ordinances, resolutions and policies concerning the displacement of
persons.
1. To meet these requirements, the owner of record must be notified in writing that
Federal financial assistance will be used in the transaction and that if agreement
cannot be reached through negotiation, that the acquisition will not take place.
There are specific URA voluntary acquisition requirements that must be met
depending on whether or not the buyer has the power of eminent domain and will
not use it (see 49 CFR 24.101(b)(1)(i)-(iv)) or if the buyer does not have the power
of eminent domain (see 49 CFR 24.101(b)(2)). Any acquisition under possible threat
of eminent domain, cannot be considered a "voluntary acquisition" (even if the seller
is willing to negotiate).
2. The relocation provisions of the Uniform Relocation Act apply to NSP -3 funds. An
unlawful occupant (see 49 CFR 24.2(a)(29)) who is displaced for an NSP -3 -funded
acquisition will not be entitled to relocation assistance and payments. However, a
lawful occupant displaced for an NSP -3 -funded acquisition will generally be eligible
Page 14 of 43
for relocation assistance and payments under URA. The DEVELOPER shall
provide appropriate relocation assistance (URA or Section 104(d)) to eligible
displaced persons as defined by applicable HUD and/or URA regulations that are
displaced as a direct result of acquisition, rehabilitation, demolition or conversion for
an NSP -3 -assisted project.
F. The DEVELOPER agrees to comply with applicable state and local civil rights ordinances
and with Title VI of the Civil Rights Act of 1964 as amended, Title VIII of the Civil Rights
Act of 1968 as amended, Section 104(b) and Section 109 of Title I of the Housing and
Community Development Act of 1974 as amended (the HCDA), Section 504 of the
Rehabilitation Act of 1973, the Americans with Disabilities Act of 1990, the Age
Discrimination Act of 1975, Executive Order 11063, and Executive Order 11246 as
amended by Executive Orders 11375, 11478, 12107 and 12086, and will include the
provisions in every subcontract or purchase order, specifically or by reference, so that
such provisions will be binding upon each of its contractors and subcontractors.
G. The DEVELOPER agrees to comply with all applicable standards, orders, or requirements
issued under Section 306 of the Clean Air Act (42 U.S.C. 1857(h)), Section 508 of the
Clean Water Act (33 U.S.C. 1368), Executive Order 11738, and Environmental Protection
Agency regulations (40 CFR part 15).
H. The DEVELOPER agrees that no funds provided, nor personnel employed under this
Agreement, shall be in any way or to any extent engaged in the conduct of political
activities in violation of Chapter 15 of Title V of the United States Code. The
DEVELOPER is prohibited from using funds provided herein or personnel employed in the
administration of the program for inherently religious activities, lobbying, political
patronage, and nepotism activities.
I. Conflict of Interest — The provisions of 24 CFR 570.611, apply to the award of any
contracts under the agreement and the selection of buyers for NSP -3 -assisted units. No
member or Delegate to the Congress of the United States shall be permitted to any share
or part of this contract or any benefit hereunder. No member, officer or employee of the
GRANTEE; or its designees, or agents; or member of the GRANTEE Council of the
GRANTEE; and no other public official of the GRANTEE who exercises any functions or
responsibilities with respect to the program during his tenure or for one (1) year thereafter,
shall have any interest direct or indirect, in any contract or subcontract, or the proceeds
thereof, for work to be performed under this agreement. Exceptions must be requested by
the DEVELOPER and the GRANTEE may grant exceptions as permitted by Regulation.
IX. Reporting, Monitoring & Access to Records
A. The DEVELOPER agrees to submit any and all reports required by HUD or the
GRANTEE. Additional reporting information is contained in Exhibit A-4 through A-7,
inclusive.
B. The DEVELOPER shall collect and maintain Project beneficiary information pertaining to
household size, income levels, racial characteristics, and the presence of Female Headed
Households in order to determine low and moderate -income benefit in a cumulative and
individual manner. Income documentation shall be in a form consistent with NSP -3
requirements.
C. The DEVELOPER agrees to provide the GRANTEE access to records and projects at any
time during project implementation or for five years after project closeout for purposes of
Page 15 of 43
verifying compliance with NSP -3 requirements and this agreement. Access shall be
immediately granted to the GRANTEE, HUD, the Comptroller General of the United
States, or any of their duly authorized representatives to any books, documents, papers,
and records of the DEVELOPER or its contractors which are directly pertinent to that
specific contract for the purpose of making audit, examination, excerpts, and
transcriptions.
D. The GRANTEE reserves the right to audit the records of the DEVELOPER any time
during the performance of this Agreement and for a period of five years after final payment
is made under this Agreement. If required by A-133, the DEVELOPER will provide the
GRANTEE with a certified audit of the DEVELOPER's records representing the Fiscal
Year during which the PROJECT becomes complete.
E. Project Closeout — The DEVELOPER's obligation to the GRANTEE shall not end until all
close-out requirements are completed. Activities during this close-out period shall
include, but are not limited to: making final payments, accounting for use of funds,
provision of all reports and records required by the GRANTEE.
X. Suspension & Termination
In accordance with 24 CFR 85.43, suspension or termination may occur if the DEVELOPER
materially fails to comply with any term of the award, and that the award may be terminated for
convenience in accordance with 24 CFR 85.44.
A. If the DEVELOPER fails in any manner to fully perform and carry out any of the terms,
covenants, and conditions of the agreement, or if the DEVELOPER refuses or fails to
proceed with the work with such diligence as will insure its completion within the time fixed
by the schedule set forth in this agreement, the DEVELOPER shall be in default and
notice in writing shall be given to the DEVELOPER of such default by the GRANTEE or an
agent of the GRANTEE. if the DEVELOPER fails to cure such default within such time as
may be required by such notice, the GRANTEE, acting by and through the GRANTEE,
may, at its option, terminate and cancel the contract.
1. In the event of such termination, all funds awarded to the DEVELOPER pursuant to
this agreement shall be immediately revoked and any approvals related to the
PROJECT shall immediately be deemed revoked and canceled. In such event, the
DEVELOPER will no longer be entitled to receive any compensation for work
undertaken after the date of the termination of this agreement, as the grant funds
will no longer be available for this project.
2. In such event, the DEVELOPER shall be entitled to receive just and equitable
compensation for any work satisfactorily completed hereunder to the date of said
termination.
3. Notwithstanding the above, the DEVELOPER shall not be relieved of liability to the
GRANTEE for damages sustained by the GRANTEE by virtue of any breach of the
contract by the DEVELOPER and the GRANTEE may withhold any payments to the
DEVELOPER for the purpose of setoff until such time as the exact amount of
damages due the GRANTEE from the DEVELOPER is determined whether by court
of competent jurisdiction or otherwise.
4. Such termination shall not effect or terminate any of the rights of the GRANTEE as
Page 16 of 43
against the DEVELOPER then existing, or which may thereafter accrue because of
such default, and the foregoing provision shall be in addition to all other rights and
remedies available to the GRANTEE under the law and the note and mortgage (if in
effect), including but not limited to compelling the DEVELOPER to complete the
project in accordance with the terms of this agreement, in a court of equity.
5. The waiver of a breach of any term, covenant or condition hereof shall not operate
as a waiver of any subsequent breach of the same or any other term, covenant, or
condition hereof.
The GRANTEE may terminate for its convenience this contract at any time by giving at
least thirty (30) days notice in writing to the DEVELOPER. If the contract is terminated by
the GRANTEE, as provided herein, the GRANTEE will reimburse for any actual and
approved expenses incurred, including those costs involved in terminating the contracts
and shutting down the work as of the date of notice, and the DEVELOPER will be paid as
compensation an amount which bears the same ratio to the total compensation as the
services actually performed bear to the total service of the DEVELOPER covered by this
contract, less payments of compensation previously made.
Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any
such disputes by negotiation. The negotiation shall be attended by representatives of
CONSULTANT with full decision-making authority and by OWNER'S staff person who
would make the presentation of any settlement reached during negotiations to OWNER
for approval. Failing resolution, and prior to the commencement of depositions in any
litigation between the parties arising out of this Agreement, the parties shall attempt to
resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator
certified by the State of Florida. The mediation shall be attended by representatives of
CONSULTANT with full decision-making authority and by OWNER'S staff person who
would make the presentation of any settlement reached at mediation to OWNER'S board
for approval. Should either party fail to submit to mediation as required hereunder, the
other party may obtain a court order requiring mediation under Section 44.102, Fla. Stats.
Any suit or action brought by either party to this Agreement against the other party relating
to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all
such matters.
XI. General Conditions
A. All notices or other communication which shall or may be given pursuant to this
Agreement shall be in writing and shall be delivered by personal service, or by registered
mail addressed to the other party at the address indicated herein or as the same may be
changed from time to time. Such notice shall be deemed given on the day on which
personally served; or, if by mail, on the fifth day after being posted or the date of actual
receipt, whichever is earlier.
GRANTEE
Collier County Board of County Commissioners
ATTN: Housing, Human and Veteran Services
Page 17 of 43
3339 Tamiami Trail E, Suite 211
Naples, Florida 34112
With a Copy to:
Collier County Office of County Attorney
ATTN: Jennifer White
3299 Tamiami Trail E, Suite 800
Naples, Florida 34112
DEVELOPER
Habitat for Humanity of Collier County, Inc.
11145 Tamiami Trail East
Naples, Florida 34113
B. Title and paragraph headings are for convenient reference and are not a part of this
Agreement.
C. in the event of conflict between the terms of this Agreement and any terms or conditions
contained in any attached documents, the terms in this Agreement shall rule.
D. No waiver or breach of any provision of this Agreement shall constitute a waiver of a
subsequent breach of the same or any other provision hereof, and no waiver shall be
effective unless made in writing.
E. The GRANTEE's failure to act with respect to a breach by the DEVELOPER does not
waive its right to act with respect to subsequent or similar breaches. The failure of the
GRANTEE to exercise or enforce any right or provision shall not constitute a waiver of
such right or provision.
F. The parties hereto agree that this Agreement shall be construed and enforced according
to the laws of the State of Florida.
G. Should any provisions, paragraphs, sentences, words or phrases contained in this
Agreement be determined by a court of competent jurisdiction to be invalid, illegal or
otherwise unenforceable under the laws of the State of Florida or the GRANTEE, such
provisions, paragraphs, sentences, words or phrases shall be deemed modified to the
extent necessary in order to conform with such laws, or if not modifiable to conform with
such laws, then same shall be deemed severable, and in either event, the remaining
terms and provisions of this Agreement shall remain unmodified and in full force and
effect.
H. The obligations undertaken by DEVELOPER pursuant to this Agreement shall not be
delegated or assigned to any other person or agency unless GRANTEE shall first consent
to the performance or assignment of such service or any part thereof by another person or
agency.
I. The Agreement shall be binding upon the parties hereto, their heirs, executors, legal
representative, successors and assigns.
J. DEVELOPER shall indemnify and save GRANTEE harmless from and against any
negligent claims, liabilities, losses and causes of action which may arise out of
Page 18 of 43
DEVELOPER's activities under this Agreement, including all other acts or omissions to act
on the part of DEVELOPER, including any person acting for or on its behalf, and, from
and against any orders, judgments, or decrees which may be entered and from and
against all costs, attorneys fees, expenses and liabilities incurred in the defense of any
such claims, or in the investigation thereof.
K. DEVELOPER and its employees and agents shall be deemed to be independent
contractors, and not agents or employees of the GRANTEE, and shall not attain any rights
or benefits under the civil service or pension ordinances of the GRANTEE, or any rights
generally afforded classified or unclassified employee; further they shall not be deemed
entitled to state Compensation benefits as an employee of the GRANTEE.
L. Funding for this Agreement is contingent on the availability of funds and continued
authorization for program activities and is subject to amendment or termination due to lack
of funds, or authorization, reduction of funds, and/or change in regulations.
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER
authorized person or agent, hereunder set their hands and
above written.
BOARD OF COUNTY COMMISSI ERS
COLLIER COUNTY, FLORIDA
By:
Fred W. Coyle, Chairman z�/r�,��
have each, respectively, by an
seals on the date and year first
AT..TEST:':.':,- f ; ,
pyJigBrack,.lerk of Courts
r ti4.i �
$tiiir't.;
Apprdvedtas ib form and
legal sufficiency:
Assistant County Attorney
Habitat for Humanity of Collier County, Inc.
A Florida not-for-profit cor o tion
By* -
First ess P int:
Title: ��<�� ; �� � ►ti fi"
ype/print witness name
� econd �Wltness
Type/print witness name
Page 19 of 43
EXHIBIT A. Project Description
A. GENERAL
Developer will be provided NSP -3 funds in the amount of Three Million Four Hundred Ninety
Five Thousand Seven Hundred Forty Nine and 001100 Dollars ($3,495249). Such funds will
be used to acquire eligible properties in the Grantees eligible target areas and to pay
associated developer fees.
B. ELIGIBLE TARGET AREAS
Properties shall only be acquired in the target areas approved by the GRANTEE and
described in the GRANTEE's NSP -3 action plan. Specifically, DEVELOPER may acquire
properties in any of the following target areas:
Target Area One Golden Gate City (HUD Neighborhood ID 1108764)
• Census Tract 0104.10
o GeolD, 12021923012630001041001
o GeolD 120219230126300010410U2
o GeolD 12021923012630001041003
• Census Tract 0104.09
o GeolD 12021923012630001040901
o GeolD 120219230126300010409U2
o GeolD 120219230126300010409U3
o GeolD 12021923012630001040904
o GeoID120219230126300010409U5
• Census Tract 0104.11
o GeolD 120219230126300010411U1
o GeolD 12021923012630001041102
o GeolD 12021923012630001041103
o GeolD 120219230126300010411R3
o GeolD 120219230126300010411R1
Target Area Two East Naples Bayshore Gateway CRA (HUD Neighborhood ID
3981140
• Census Tract 0107.01
o GeolD 120219230199999010701U4
o GeolD 120219230199999010701U1
o GeolD 120219230199999010701U2
o GeolD 120219230199999010701 U3
o GeolD 120219230199999010701R2
C. ELIGIBLE ACTIVITIES
The following activities are eligible under this Agreement and are more thoroughly described
In the NSP Notice.
NSP -Eligible Use (A) — Establish financing mechanisms for purchase and
redevelopment of foreclosed upon homes and residential properties, including such
mechanisms as soft -seconds, loan loss reserves, and shared -equity loans for low- and
moderate -income homebuyers.
Page 20 of 43
As part of an activity delivery cost for an eligible activity as defined in 24 CFR
570.206.
Also, the eligible activities listed below to the extent financing mechanisms are
used to carry them out.
NSP -Eligible Use (B) -- Purchase and rehabilitate homes and residential properties that
have been abandoned or foreclosed upon, in order to sell, rent, or redevelop such
homes and properties.
24 CFR 570.201(a) Acquisition, (b) Disposition, (i) Relocation, and (n) Direct
homeownership assistance (as modified below):
0 24 CFR 570.202 eligible rehabilitation and preservation activities for
homes and residential properties.
o HUD notes that any of the activities listed above may include required
homebuyer counseling as an activity delivery cost.
NSP -Eligible Use (C) — Establish and operate land banks for homes and residential
properties that have been foreclosed upon.
• 24 CFR 570.201(a) Acquisition and (b) Disposition
o HUD notes that any of the activities listed above may include required
homebuyer counseling as an activity deliver cost.
NSP -Eligible Use (D) — Demolish blighted structures.
24 CFR 570.201(d) Clearance for blighted structures only.
NSP -Eligible Use (E) — Redevelop demolished or vacant properties as housing.
24 CFR 570.201(a) Acquisition, (b) Disposition, (c) Public facilities and
improvements, (e) Public services for housing counseling, but only to the extent
that counseling beneficiaries are limited to prospective purchasers or tenants of
the redeveloped properties, (i) Relocation, and (n) Direct homeownership
assistance (as modified below):
o 24 CFR 570.202 Eligible rehabilitation and preservation activities for
demolished or vacant properties.
o 24 CFR 570.204 Community based development organizations.
o HUD notes that any of the activities listed above may include required
homebuyer counseling as an activity delivery cost.
D. REHABILITATION OR REDEVELOPMENT
NSP -assisted property subject to this Agreement shall be rehabilitated or redeveloped to the
extent necessary to comply with applicable laws, codes, and other requirements relating to
housing safety, quality, and habitability in order to sell, rent, or redevelop such homes and
properties. Developer led rehabilitation is undertaken pursuant to 24 CFR 570.202(b)(1).
New housing construction is undertaken pursuant to 24 CFR 570.204, or the NSP notice
published on October 6, 2008, as amended.
Pursuant to the Grantee's NSP -3 action plan, NSP -assisted property is required to meet or
exceed local and state building codes; the current code applied in Collier County is 2007
Florida Building Code. Furthermore, HERA defines rehabilitation to include improvements to
Page 21 of 43
increase the energy efficiency or conservation of such homes and properties or to provide a
renewable energy source or source for such homes and properties. Such improvement are
also eligible under the regular CDBG program.
Developer is subject to Section 504 of the Rehabilitation Act of 1973 and the Fair Housing
Act, including their respective provisions related to physical accessibility standards for
person with disabilities. See 24 CFR Part 8; 24 CFR 100.205; See also 24 CFR 570.487
and 24 CFR 570.602.
E. ELIGIBLE INCOME LEVELS OF BUYERS
NSP -assisted property subject to the Agreement shall be used with respect to individuals
and families whose income does not exceed 120 percent of area median income. However,
not less than twenty-five (25) percent of the funds expended by Grantee in acquiring the
properties subject to this Agreement shall be used to house individuals or families whose
income do not exceed 50 percent of the area median income ("11-125 Requirement').
To ensure compliance with the NSP LH25 Requirement, DEVELOPER shall ensure that
Nine Hundred Seventy One Thousand Forty Two and 00/100 Dollars ($971,042) be
expended to comply with the LH25 Requirement.
F. MAXIMUM SALES PRICE
If an abandoned or foreclosed -upon home or residential property is purchased, redeveloped,
or otherwise sold to an individual as a primary residence, then such sale shall be in amount
equal to or less than the cost to acquire and redevelop or rehabilitate such property up to a
decent, safe, and habitable condition. The maximum sales price for a property is
determined by aggregating all costs of acquisition, rehabilitation, and redevelopment
(including related activity delivery costs, which generally include, among other things, costs
related to the sale of the property).
G. HABITAT FOR HUMANITY AFFILIATES
Grantee hereby designates Habitat for Humanity of Collier County, Inc. as a Developer of
the County's NSP. Pursuant to a HUD issued NSP Policy Alert titled "Guidance for Habitat
for Humanity Affiliates," dated January 12, 2011, the following clarifications are hereby
provided.
a. DEVELOPER
Developers are program beneficiaries and thus distinct from subrecipients,
grantee employees, and contractors. Developers may receive NSP funds from
the Grantee. Developer -led rehabilitation is undertaken pursuant to 24 CFR
570.202(b)(1). New housing construction is undertaken pursuant to 24 CFR
570.204, or the NSP notice published on October 6, 2008, as amended.
Habitat for Humanity affiliates designated as developers:
• Do not have to follow federal procurement rules;
• May charge developer fees;
• Do not have to follow OMB Circulars;
• Are not required to treat revenues as program income
Page 22 of 43
b. SALES PRICE VALUATION
In addition to the information contained above under Maximum Sales Price," the
cost of donated materials and professional services may also be included in the
base for determining the maximum sales price under Section 2301(d)(3) of
HERA. The cost of donated materials must be based on fair market value at the
time of donation. Estimates of the value of unskilled or sweat -equity labor may
not be included in the total development cost. Moreover, the costs of donated
professional services and materials may not be reimbursed by the NSP grant.
c. DEVELOPMENT SUBSIDY
In some instances, the total development cost of rehabbed and/or newly
constructed NSP units will be greater than the current market value of such unit.
In such situations, NSP funds can be used to fill the appraisal gap, and will be
considered a development subsidy. Grantee may not apply affordability
instruments to NSP funds used as a development subsidy. This subsidy will be
considered a "sunk cost" and is considered an eligible use of NSP funds.
d. DETERMINATION OF NO UNDUE ENRICHMENT
Pursuant to the terms and conditions of this Agreement, Developer shall be
investing Developer's own funds, time, and effort when undertaking the project
described herein. Furthermore, Developer is a not-for-profit provider of
affordable housing. Based upon these facts, as well as the rules and regulations
applicable to NSP, Grantee has determined that there is no undue enrichment
should Developer recapture and retain the net proceeds from sale of properties
assisted through this Agreement.
H. INDEMNIFICATION
To the maximum extent permitted by Florida law, the Developer shall indemnify and hold
harmless Collier County, its officers and employees from any and all liabilities, damages,
losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals'
fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct
of the Developer or anyone employed or utilized by the Developer in the performance of this
Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified
party or person described in this paragraph. This section does not pertain to any incident
arising from the sole negligence of Collier County. The foregoing indemnification shall not
constitute a waiver of sovereign immunity beyond the limits set forth in Section 768.28,
Florida Statutes.
I. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES
No organization or individual shall offer or give, either directly or indirectly, any favor, gift,
loan, fee, service or other item of value to any County employee, as set forth in Chapter
112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, and County
Administrative Procedure 5311. Violation of this provision may result in one or more of the
following consequences: a. Prohibition by the individual, firm, and/or any employee of the
firm from contact with County staff for a specified period of time; b. Prohibition by the
Page 23 of 43
individual and/or firm from doing business with the County for a specified period of time,
including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate
termination of any contract held by the individual and/or firm for cause.
Page 24 of 43
EXHIBIT A-1. Affordability Requirements
GENERAL
Developer will ensure that all properties subject to this Agreement comply with the affordability
provisions of the HOME Investment Partnerships Program as contained in 24 CFR 92.254
relating to qualification as affordable housing for homeownership. The Developer, at its sole
discretion, may impose greater restrictions so long as the restrictions are at level at or above
those of the HOME Investment Partnerships Program.
HOMEOWNERSHIP: LONG TERM AFFORDABILITY
The NSP -assisted housing must meet the affordability requirements for not less than the
applicable period specified in the following table, beginning after project completion. The per
unit amount of NSP funds and the affordability period that they trigger are described more fully
below under Recapture Provisions.
Homeownership assistance NSP
Minimum period of
amountper-unit
affordability in years
Under $15,000 ...........................
5
$15,000 to $40,000 ......................
10
Over $40,000 ..............................
15
Recapture Provisions
The recapture provisions will ensure that the Developer recoups all or a portion of the NSP
assistance benefiting the homebuyer, if the housing does not continue to be the principal
residence of the family for the duration of the period of affordability. The period of affordability is
based upon the total amount of NSP funds subject to recapture described above.
The Developer may choose to recapture the entire amount of NSP assistance or a reduced
amount on a prorata basis for the time the homeowner has owned and occupied the housing
measured against the required affordability period. The net proceeds may be divided
proportionally as set forth in the following mathematical formulas:
NSP investment X Net proceeds = NSP amount to Developer
NSP investment + homeowner investment
homeowner investment X Net proceeds = amount to homeowner
NSP investment + homeowner investment
The Developer may permit the homebuyer to recover the homebuyer's entire investment (down
payment and capital improvements made by the owner since purchase) before recapturing the
NSP investment. Any NSP investment recaptured by the Developer shall remain with the
Developer for future use toward other NSP -eligible activities.
Page 25 of 43
EXHIBIT A-2. Disbursement
GENERAL
Developer shall invest its own funds to complete the rehabilitation or development of the
properties associated with this Agreement thereby assuming risk associated with the project.
To compensate Developer for such risk, and for providing NSP -related goods and services,
such as, but not necessarily limited to, residential rehabilitation, eligible buyer identification, and
final disposition, Developer shall be paid a developer fee.
In addition to payment of developer fees, funding under this Agreement may be used for the
acquisition of eligible properties.
AMOUNT
Grantee shall pay Developer a Ten Thousand and 00/100 Dollars ($10,000) developer fee for
each of the properties acquired through this Agreement. The maximum combined developer
fee paid by Grantee to Developer through this Agreement shall be Two Hundred Seventy
Thousand and 00/100 Dollars ($270,000); this amount represents a cumulative of developer
fees paid for each of the properties acquired through this Agreement.
Grantee shall reimburse Developer a maximum One Hundred Fifty Thousand and 00/100
Dollars ($150,000) for each property acquired through this Agreement, unless a higher amount
is approved in writing by Grantee; however, such reimbursed amount may not exceed the actual
cost of acquisition. The maximum combined reimbursement paid by Grantee to Developer
through this Agreement shall be Three Million Two Hundred Twenty Five Thousand Seven
Hundred Forty Nine and 00/100 Dollars ($3,225,749); this amount represents a cumulative of
reimbursements paid for each of the properties acquired through this agreement
METHOD OF PAYMENT
Grantee shall reimburse Developer a maximum One Hundred Fiftv Thousand and 00/100
Dollars ($150,000) for each property acquired through this Agreement; however, such
reimbursed amount may not exceed the actual cost of acquisition. To secure payment following
acquisition, Developer shall submit to Grantee the following supporting materials in a format
acceptable to Grantee:
1. HUD -1 Settlement Statement
2. Proof of funds transfer
a. i.e. evidence of wire transfers
3. Bank account statements detailing funds transfer
4. Appraisal
5. Attestation form to be provided by Grantee
Grantee shall pay Developer one-half ($5,000 of a total per property developer fee of $10,000)
of the developer fee per property upon acquisition of such property and one-half ($5,000 of a
total per property developer fee of $10,000) at final sale to an income -eligible person or
household.
To secure payment following acquisition ($5,000 of a total per property developer fee of
$10,000), Developer shall submit to Grantee the following supporting materials in a format
acceptable to Grantee:
Page 26 of 43
1. HUD -1 Settlement Statement
2. Proof of funds transfer
a. i.e. evidence of wire transfers
3. Bank account statements detailing funds transfer
4. Appraisal
5. Attestation form to be provided by Grantee
To secure payment following final sale ($5,000 of a total per property developer fee of $10,000),
Developer shall submit to Grantee the following supporting materials in a format acceptable to
Grantee:
1. HUD -1 Settlement Statement
2. Appraisal
3. Sale Contract
4. Attestation form to be provided by Grantee
Page 27 of 43
EXHIBIT A-3. Grant Agency Requirements
APPLICABLE LAWS AND REGULATIONS
Certain State and Federal laws, regulations, and Executive Orders are applicable in part or in
whole to the NSP. The applicable laws, regulations, and Executive Orders, classified generally
by compliance area, include but may not be limited to the following.
GENERAL REQUIREMENTS
The Housing and Community Development Act of 1974, as amended and as
implemented by the most current HUD regulations (24 CFR Part 570).
Federal Register Docket No. FR -5447-N-01: Notice of Formula Allocations and Program
Requirements for Neighborhood Stabilization Program Formula Grants; October 19, 2010.
U.S. Department of Housing and Urban Development's Playing by the Rules: A Handbook
for CDBG Sub -recipients on Administrative Systems.
CIVIL RIGHTS
• Title VI - Civil Rights Act of 1964.
• Section 109 - Title I - Housing and Community Act of 1974.
• Title VIII of the Civil Rights Act, 1968 (Fair Housing Act), as amended. 42 U.S.C. 3601.
• Section 504 of the Rehabilitation Act of 1973, and the Americans with Disabilities Act of
1990.
• Executive Order 11246 - Equal Employment Opportunity, as amended by Executive
Order 11375, Parts 11 and III.
• Executive Order 11063 - Equal Employment Opportunity, as amended by Executive
Order 12259.
• Section 3 of the Housing and Development Act of 1968, as amended Section 118 of Title
1, Community Development and Housing Act, 1974.
• Age Discrimination Act of 1975.
• Executive Order 12432: National Priority to Develop Minority and Women Owned
Businesses.
• Section 504 of the Rehabilitation Act of 1973 and implementation regulation (24 CFR
Part 8).
ACQUISITION AND RELOCATION
• The Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970
(46 U.S.C. 4601 and regulations at 49 CFR, Part 24).
HOUSING
• The Truth in Lending Act (Regulation Z).
• Title I Consumer Protection Act (PL 90321).
• The Lead Base Paint Poisoning Prevention Act (42 U.S.C. 4831-5 et al.) and HUd
implementing regulations (24 CFR Part 35).
• The Residential Lead -Based Paint Hazard Reduction Act of 1993 (PL 102-550).
• The National Manufactured Housing Construction and Safety Standards Act of 1974 (42
U.S.C., 5401 et. seq., as amended).
• Manufactured Housing Act (O.C.G.A. Sections 8-2-130 and 160 et. seq.).
Page 28 of 43
• Construction Industry Licensing Board Act (O.C.G.A. Section 43-14-8).
• The Fire Administration Authorization Act of 1992 (PL 102-522).
ENVIRONMENTAL
• Title I of the Housing and Community Development Act, Section 104(8) — as amended
(42 U.S.C. 5304) and published in 24 CFR Part 58.
• Section 306 of the Clear Air Act (42 U.S.C. 1857(h))
Section 508 of the Clean Water Act (33 U.S.C. 1368).
• Executive Order 11738, and Environmental Protection Agency regulations (40 CFR part
15).
• Energy Policy and Conservation Act (Pub. L.94-163).
LABOR STANDARDS
• The Contract Work Hours and Safety Standards Act (40 U.S.C. 327-330) as
supplemented by Department of Labor regulations.
• The Davis -Bacon Act (40 U.S.C. 276(a) to (a-7), as supplemented by Department of
Labor Regulations.
• The Davis -Bacon Act (42 U.S.C. 5310).
• The Copeland "Anti -Kickback" Act (18 U.S.C. 874) as supplemented by Department of
Labor regulations.
* Conditions prohibiting inherently religious activities (24 CFR 570.2000)).
HOUSING REHABILITATION REQUIREMENTS
• The Common Rule 24 CFR 85 — applies if the direct party of the construction contract.
This rule requires a competitive procurement.
• Federal Labor Standards — Only in certain situations. Davis -bacon wage rate are
applicable when NSP funds are used for rehabilitation of more than 8 housing units in
one project.
• Lead -Based Paint Hazard Elimination (24 CFR Part 35) — These rules include
inspection, testing, risk assessments, hazard control or abatement, safe work practices,
clearance and notification/disclosure requirements.
• Section 3 Clause of the Urban Development Act of 1968, and as implemented by HUD
regulations at 24 CFR Part 135 applies (regardless of the dollar amount of the contract)
in the following situations:
o If the Recipient contracts directly for rehabilitation services or acts as an agent
for the homeowner, i.e., signs the rehabilitation contract.
o If the Recipient provides homeowners with a list of contractors eligible to
participate in the local rehabilitation program, the Recipient should assure that
eligible Section 3 business concerns located or owned in part by residents of the
area are also included on the list.
o If the individual homeowner contracts directly for rehabilitation services and the
Recipient is not a party to the contract, the Section 3 requirements do not have to
be followed.
• Section 104(d) of the Housing and Community Development Act is applicable if rental
units are converted to non- "low and moderate income dwelling units" or if occupied or
Page 29 of 43
occupiable housing units are demolished. See HUD regulations at 24 CFR Part 570.606
and 24 CFR Part 42.
The Uniform Relocation Assistance and Real Property Acquisition Act of 1970, as
amended, and as implemented by DOT regulations 49 CFR Part 24, is applicable if
tenants or homeowners (regardless of income) are displaced in conjunction with a NSP
activity.
The Truth -In -Lending Act (Regulation Z) (USC 1601, et. seq.) which applies to any loan
transaction between the Recipient and the homeowner provided the Recipient meets the
criteria of being a "creditor", as defined by the Federal Reserve System
EQUAL OPPORTUNITY FAIR HOUSING, AND ACCESSIBILITY
GENERAL
The regulations pursuant to Title I of the Housing and Community Development Act require
applicants to assure through certification that all activities will be conducted in accordance with
Section 109 of the Act (the nondiscrimination clause), Title VI of the Civil Rights Act of 1964,
Title Vlll of the Civil Rights Act of 1968, and Executive Orders 11246 and 11063. These
requirements are briefly described below:
1. Title VI of Civil Rights Act of 1968 Nondiscrimination in any programs or activities receiving
Federal financial assistance.
2. Section 109 of Title I — Housing and Community Development Act of 1974 Nondiscrimination
in any program or activity subject to the provisions of this title. No person in the United States
shall on the ground of race, color, national origin, or sex, be excluded from participation in, be
denied the benefits of, or be subjected to discrimination under any program or activity funded in
whole or part under this Title. Any prohibition against discrimination on the basis of age under
the Age Discrimination Act of 1975 or with respect to an otherwise qualified handicapped
individual as provided in Section 504 of the Rehabilitation Act of 1973 shall also apply to any
such program or activity.
3. Title Vlll of the Civil Rights Act of 1968, as amended. Prohibition against discrimination
based on sex.
4. The Fair Housing Law Provides protection against the following acts, if they are based on
disability, race, color, religion, sex, national origin, or family status:
• Refusing to sell or rent to, deal or negotiate with any person Discriminating in terms or
conditions for buying or renting Housing
• Discriminating by advertising that housing is available only to persons of a certain family
status, race, color, religion, sex, or national origin
• Denying that housing is available for inspection, sell or rent when it really is available
• "Blockbusting" - For profit, persuading owners to sell or rent housing by telling them that
minority groups are moving into the neighborhood
• Denying to anyone the use of or participation in any real estate services, such as
brokers' organizations, multiple listing services or other facilities related to the selling or
renting of housing
• Denying or making different terms or conditions for home loans by commercial lenders,
such as banks, savings and loan associations and insurance companies
Page 30 of 43
5. Executive Order 11063 - Equal Opportunity in Housing, as amended by Executive Order
12259 — All departments and agencies are directed to take all action necessary and appropriate
to prevent discrimination in housing and related facilities owned or operated by the Federal
Government or provided with Federal financial assistance and in the lending practices with
respect to residential property and related facilities (including land to be developed for
residential use) of lending institutions, insofar as such practices relate to loans insured or
guaranteed by the Federal Government.
6. Executive Order 11246 — Equal Employment Opportunity, as amended by Executive Order
11375. Part II - Employment under Federal contracts. Non-discrimination in employment by
government contractors and subcontractors. Part III - Federally assisted construction contracts.
Non-discrimination in employment under federally assisted construction contracts. Parts 11 and
III are administered by the Department of Labor.
7. Section 3 of the Housing and Development Act of 1968, as amended and as implemented by
HUD regulations at 24 CFR Part 135 Section 3 provides that to the greatest extent feasible,
training and employment opportunities shall be made available to lower income residents of
project areas and that contracts be awarded to small businesses located within the project area
or owned in substantial part by project area residents.
SECTION 504 REQUIREMENTS
Local government recipients and subrecipients must comply with Section 504 of the
Rehabilitation Act of 1973, as amended. This requirement is similar to the "Americans with
Disability Act" (ADA) which is also applicable. HUD published implementation regulations (24
CFR Part 8) as a final rule on June 2, 1988. The general requirement is that no otherwise
qualified Individual with a disability (physical or mental) shall, because a recipient's facilities are
inaccessible to or unusable by Individuals with disabilities, be excluded from participation in,
denied benefits, or otherwise be subjected to discrimination under any program or activity that
receives NSP assistance. The definition of disability includes physical and mental factors and
also includes those who may be regarded as handicapped (such as the spouse or children of a
person with AIDS). Both building accessibility and employment practices are covered by Section
504.
AFFIRMATIVELY FURTHERING FAIR HOUSING
Any Subrecipient must certify that it will affirmatively further fair housing, mandated under 24
CFR 570.602.
SECTION 3 OF THE HOUSING AND URBAN DEVELOPMENT ACT OF 1968
As amended, provides that, to the greatest extent feasible, opportunities for training and
employment shall be given to recipients of public housing and lower-income residents of the unit
of local government or the metropolitan area (or non -metropolitan county) in which the project is
located. Contract work in connection with such projects shall be awarded to business concerns
which are owned in substantial part by persons residing in the same metropolitan area (or
nonmetropolitan county) as the project, employ Section 3 residents in full-time positions, or
subcontract with businesses which provide economic opportunities to lower income persons.
Section 3 Regulations 24 CFR 135.
§ 135.38 Section 3 clause.
Page 31 of 43
All section 3 covered contracts shall include the following clause (referred to as the section 3
clause);
A. The work to be performed under this contract is subject to the requirements of section 3 of
the Housing and Urban Development Act of 1968, as amended, 12 U.S.C. 1701u (section 3).
The purpose of section 3 is to ensure that employment and other economic opportunities
generated by HUD assistance or HUD -assisted projects covered by section 3, shall, to the
greatest extent feasible, be directed to low- and very low-income persons, particularly persons
who are recipients of HUD assistance for housing.
B. The parties to this contract agree to comply with HUD"s regulations in 24 CFR part 135,
which implement section 3. As evidenced by their execution of this contract, the parties to this
contract certify that they are under no contractual or other impediment that would prevent them
from complying with the part 135 regulations.
C. The contractor agrees to send to each labor organization or representative of workers with
which the contractor has a collective bargaining agreement or other understanding, if any, a
notice advising the labor organization or workers" representative of the contractor's
commitments under this section 3 clause, and will post copies of the notice in conspicuous
places at the work site where both employees and applicants for training and employment
positions can see the notice. The notice shall describe the section 3 preference, shall set forth
minimum number and job titles subject to hire, availability of apprenticeship and training
positions, the qualifications for each; and the name and location of the person(s) taking
applications for each of the positions; and the anticipated date the work shall begin.
D. The contractor agrees to include this section 3 clause in every subcontract subject to
compliance with regulations in 24 CFR part 135, and agrees to take appropriate action, as
provided in an applicable provision of the subcontract or in this section 3 clause, upon a finding
that the subcontractor is in violation of the regulations in 24 CFR part 135. The contractor will
not subcontract with any subcontractor where the contractor has notice or knowledge that the
subcontractor has been found in violation of the regulations in 24 CFR part 135.
E. The contractor will certify that any vacant employment positions, including training positions,
that are filled (1) after the contractor is selected but before the contract is executed, and (2) with
persons other than those to whom the regulations of 24 CFR part 135 require employment
opportunities to be directed, were not filled to circumvent the contractor's obligations under 24
CFR part 135.
F. Noncompliance with HUD"s regulations in 24 CFR part 135 may result in sanctions,
termination of this contract for default, and debarment or suspension from future HUD assisted
contracts.
G. With respect to work performed in connection with section 3 covered Indian housing
assistance, section 7(b) of the Indian Self -Determination and Education Assistance Act (25
U.S.C. 450e) also applies to the work to be performed under this contract. Section 7(b) requires
that to the greatest extent feasible (i) preference and opportunities for training and employment
shall be given to Indians, and (ii) preference in the award of contracts and subcontracts shall be
given to Indian organizations and Indian -owned Economic Enterprises. Parties to this contract
that are subject to the provisions of section 3 and section 7(b) agree to comply with section 3 to
the maximum extent feasible, but not in derogation of compliance with section7(b).
Page 32 of 43
Pursuant to 24 CFR 24, all NSP grantees are required to verify that any/all persons, contractors,
consultants, businesses, sub-recipients, etc. that are conducting business with the grantee,
including any city/county or the grantee itself, are not presently debarred, suspended, proposed
for debarment, declared ineligible, or voluntarily excluded from participation in the covered
transaction or in any proposal submitted in connection with the covered transaction. Verification
will be checked through the Excluded Parties Listing System (at website: www.epls.gov).
Page 33 of 43
EXHIBIT A-4. Reporting
REPORTING SCHEDULE
The Developer shall submit quarterly reports to Grantee based on the following schedule.
Reports shall be submitted according to this schedule as long as this Agreement is in force:
Activit Reporting Period
Report Due Date
October 15 — December 31g
Januar 10
Januar 31' — March 31"
Aril 10
A ril 13 — June 30
Jul 10
Jul 15 — September 30
October 10
NSP -3 DEVELOPER AGREEMENT
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
Date Submitted:
Activity Reporting Period:
Contact Person:
Telephone:
Email:
GENERAL
1. Activity Status or Milestones — describe any significant actions taken or outcomes
achieved during this reporting period.
2. Future Actions — what significant actions or outcomes are expected during the next
reporting period?
3. Obstacles — describe any potential obstacles, challenges, or issues that may cause
delay.
Page 34 of 43
ACTIVITY STATUS
Complete the following information by entering the appropriate numbers for this reporting period
in the tables below. Do not duplicate information from previous reporting periods.
UN
-=Ttits.J�e ott�n _Pedocl�
No. Active Projects
No. Projects Complete
No. Properties Demolished
No. Properties Sold
TOTAL
HOUSEHOLD INFORMATION
Complete these tables for those properties sold during this reporting period.
• �� � —��,� �,.�� _ � � : -a- �� � ��'his"�e ortira P;�t7od
No. Extremet -Low Income Households 0-30% AMI
No. Ver -Law Income Households 31-50%AMI
No. Low -Income Households 51-80%AMI
No. Moderate -Income Households 81-920% AMI
No. Female Head of Households
TOTAL
RACE AND ETHNICITY BENEFICIARIES
¢ y a =� a cflt. tVQ1S . 3n1C'
White
Black or African American
Asian
American Indian or Alaskan Native
Native Hawaiian or Other Pacific Islander
American Indian/Alaska Native and White
Asian and White
Black/African American and White
American Indian/Alaskan Native and Black/African American
Other Multi -Racial
TOTAL
Page 35 of 43
EXHIBIT A-5. Monitoring
DATE:
HOMEBUYER(S) NAME:
PROPERTY ADDRESS:
DEVELOPER shall submit the following completed form upon final sale of each property
associated with this Agreement.
SECTION A: PARTICIPANT ELIGIBILITY
3.
4.
the Developer correctly apply income inclusions and exclusions for the El❑ ❑
sen income definition and was the calculation performed correctly? Yes No N/A
Basis for Conclusion:
household income supported with source documentation? ❑ ❑ ❑
Yes No N/A
Basis for Conclusion:
Was the family's annual income less than or equal to 120% of the area
❑ ❑ ❑
median income (or less than or equal to 50% if the unit was designated for
Yes No N/A
he Low Income set-aside)?
Describe Basis for Conclusion:
Does the file document that the homebuyer received and completed at -leasl
❑ ❑ ❑
eight hours of homebuyer counseling from a HUD -approved housing
Yes No N/A
counseling agency before purchase?
Describe Basis for Conclusion:
Page 36 of 43
5.
] El 0
ruse
es the written agreement with the homebuyer specify that the buyer mus
the property as a principal residence throughout the period of Yes No NIA
be Basis for Conclusion:
6.
Does the written agreement specify remedies or actions the Grantee must F1 E] F]
oke if the principal residence requirement is not met for the affordability Yes No N/A
period?
Describe Basis for Conclusion:
SECTION B: AFFORDABILITY PROVISIONS
7.
rreocaptureworr"resaale
es the ten greement with the homebuyer include the required [�
provisions, as described in the Developer Agreement? Yes No N/A
Basis for Conclusion:
8.
as the correct period of affordability established for the project, based n []
upon the total amount of NSP assistance provided to the homebuyer if Yes No N/A
under a resale provision or the direct subsidy provided with NSP funds, if
under a recaptureprovision?
Describe Basis for Conclusion:
9.
Were legal documents recorded: deed restriction or covenant running with n F1 n
he land if the property is under resale provisions, or note/deed of trust and Yes No N/A
mortgage for recapture provisions?
Describe Basis for Conclusion:
Page 37 of 43
SECTION C: PROPERTY STANDARDS
MA
11.
the project was constructed before 1978, did the Developer comply with
ad -safe housing requirements at 24 CFR Part 35?
Basis for Conclusion:
the project involved rehabilitation or new construction of a unit, does the
ial inspection confirm that the property met all applicable property
andards at completion?
Basis for Conclusion:
Prepared By:
Telephone: Email:
Page 38 of 43
❑ ❑ ❑
(es No N/A
❑ ❑ ❑
(es No N/A
EXHIBIT A-6. Income Certification
Neighborhood Stabilization Program 3
Habitat for Humanity of Collier County, Inc.
INSTRUCTIONS
Submit completed form, including appropriate supporting documentation, to Grantee to obtain
approval prior to the sale of a property associated with this Agreement to an eligible person or
household.
Effective Date:
A. Household Information
Member Names — All Household Members Relationship Age
M
1
2
3
4
5
6
7
8
B. Assets: All Household Members, Including Minors
Income
Member Asset Description Cash Value from
Assets
1
2
3
4
5
6
7
8
Total Cash Value A Assets B(a)
Total Income from Assets B{b}
If line B(a) is greater than $5,000, multiply that amount by the rate specified
by HUD (applicable rate 2.0%) and enter results in B(c), otherwise leaveB c
blank.
Page 39 of 43
C. Anticipated Annual income. Includes Unearned Income and Support Paid on
Behalf of Minors
Member
Wages I Benefits I Public Other
Salaries Pensions Assistance Income
(include tips,
commissions, Asset
bonuses, and Income
overtime
1
(Enter the
greater of
2
box B(b) or
box B(c),
3
4
above, in
box C(e)
5
below)
6
7
(a) (b) (c) (d) (e)
Totals
Enter total of items C(a) through C(e).
This amount is the Annual Anticipated Household Income.
D. Recipient Statement. The information on this form is to be used to determine maximum
income for eligibility. I/we have provided, for each person set forth in Item A, acceptable
verification of current and anticipated annual income. I/we certify that the statements are
true and complete to the best of my/our knowledge and belief and are given under
penalty of perjury.
WARNING: Florida Statutes 817 provides that willful false statements or misrepresentations concerning income and
assets or liabilities relating to financial condition is a misdemeanor of the first degree and is punishable by fines and
imprisonment provided under S. 775.082 and 775.083.
Signature of Head of Household
Date
Signature of Spouse or Co -Head of Household Date
Adult Household Member (if applicable)
uate
Adult Household Member (if applicable) Date
Page 40 of 43
E. NSP Grantee Statement: Based on the representations herein, the family or
individual(s) named in Item A of this Income Certification is/are eligible under the
provisions of the NSP. The family or individual(s) constitute(s) a:
Very -Low Income (VLI) Household means and individual or family whose
annual income does not exceed 50 percent of the area median income as
determined by the U.S. Department of Housing and Urban Development with
adjustments for household size.
(Maximum Income Limit $ )•
Low -Income (LI) Household means and individual or family whose annual
income does not exceed 80 percent of the area median income as determined by
the U.S. Department of Housing and Urban Development with adjustments for
household size.
(Maximum Income Limit $ )
Moderate -income (MOD) Household means and individual or family whose
annual income does not exceed 120 percent of the area median income as
determined by the U.S. Department of Housing and Urban Development with
adjustments for household size.
(Maximum Income Limit $ )
Based upon the (year) income limits for the Naples -Marco Island Metropolitan
Statistical Area (MSA) of Collier County, Florida.
Signature of the NSP Administrator or His/Her Designated Representative:
Signature
Printed Name
F. Household Data
nate
ime
Number of Persons
B Race ! Ethnicit
B Age
White
Black
Hispanic
Asian
American
Indian
Other
0-25
26-40
41-61
62+
:1
Special
Target ! Special Needs
Check all that a I
Farm Worker
Developmentally
Homeless
Elderly
Other
Disabled
:1
NOTE: Information concerning the rate or ethnicity of the occupants is being gathered for statistical use only. No
occupant is required to give such information he or she desires to do so, and refusal to give such information will not
affect any right he or she has an occupant.
Page 41 of 43
EXHIBIT A-7. Quarterly Performance Report Data
GENERAL
Grantee is required to submit to HUD, through the Disaster Recovery Grant Reporting System
("DRGR") Quarterly Performance Reports ("QPR"). To facilitate in the preparation of such
reports, Developer shall submit the information contained herein within ten (10) days of the end
of each calendar quarter.
1. OVERALL PROGRESS NARRATIVE
Describe overall progress made in operating the NSP.
2. FINANCIAL DATA
Provide (a) number of properties acquired, (b) program funds expended, and (c)
program funds obligated.
3. ACTIVITY PROGRESS NARRATIVE
Described progress made within the following three (3) activities: (a) acquisition,
rehabilitation, resale LMMI, (b) acquisition rehabilitation, resale LH25, and (c) land bank.
4. PROPERTY DATA
Provide the address of each property where funds were expended or obligated this
reporting period.
5. DEMOGRAPHIC DATA
Provide the following data for each household assisted this reporting period: (a) race, (b)
Hispanic/Latino (yes/no), (c) female head of household (yes/no), and (d) income level.
Page 42 of 43
EXHIBIT B. Budget
GENERAL
Developer will be provided NSP -3 funding by the Grantee for the purpose of acquiring eligible
properties for final disposition to NSP -eligible persons or families, including payment of
developer fees.
Grantee shall pay Developer a Ten Thousand and 00/100 Dollars ($10,000) developer fee for
each of the properties acquired through this Agreement. The maximum combined developer
fee paid by Grantee to Developer through this Agreement shall be Two Hundred Seventy
Thousand 00/100 Dollars ($270,000); this amount represents a cumulative of developer fees
paid for each of the properties acquired through this Agreement.
Grantee shall reimburse Developer a maximum One .Hundred Fifty Thousand and 00/100
Dollars ($150,000) for each property acquired through this Agreement, unless a higher amount
is adproved in writing by Grantee; however, such reimbursed amount may not exceed the actual
cost of acquisition. The maximum combined reimbursement paid by Grantee to Developer
through this Agreement shall be Three Million Two Hundred Twenty Five Thousand Seven
Hundred Forty Nine and 00/100 Dollars ($3,225,749); this amount represents a cumulative of
reimbursements paid for each of the properties acquired through this agreement
INCOME TARGETING
Funds associated with this Agreement shall be spent within the following income targets.
Line Item
Amount
County Administration
$388,416
Habitat for Humanity Developer Fee
$270,000
Low -Income Set Aside 50% AMI
$971,042
51 % AMI -- 80% AMI
$1,504,707
81% AMI —120% AMI
$750,000
TOTAL
$3,884,165
It is understood and agreed that funds will be used according to the approved budget.
Developer has the authority to reallocate $25,000 per income category, but shall not expend
less than the Low Income Set Aside allocation of $971,042. Should the Developer determine
that the reallocation is necessary, a prior notification and written approval shall be duly signed
by the Developer and the Director of HHVS. Reallocations above $25,000 between income
categories will require prior Grantee approval.
Page 43 of 43
RECEIVeD
A � � 2013
MEMORANDUM VETERAN ,8EBVBCES
Date: January 14, 2013
To: Barbetta Hutchinson, Operations Coordinator
Housing, Human & Veteran Services
From: Teresa Cannon, Deputy Clerk
Minutes & Records Department
Re: Developer Agreement w/Habitat for Humanity of Collier County,
Inc.
Attached for your records is a certified copy of the Agreement referenced above,
(Item #16D4) adopted by the Board of County Commissioners on Tuesday,
January 8, 2013.
if you have any questions, please feel free to contact me at 252-8411.
Thank you.
Attachment
STATE OF FLORIDA)
COUNTY OF COLLIER)
I, DWIGHT E. BROCK, Clerk of Courts in and for the
Twentieth Judicial Circuit, Collier County, Florida, do
hereby certify that the foregoing is a true and correct
copy of:
Neighborhood Stabilization Program 3
Amendment #1 to Developer Agreement with Habitat for Humanity of
Collier County, Inc.
Agenda Item from the January 8, 201.3, BCC Meeting
Item #16D4
WITNESS my hand and the official seal of the Board of
County Commissioners of Collier County, Florida, this 14th
day of January, 2013.
DWIGHT E. BROCK
Clerk of Courts and Clerk
Ex -officio to Board;,of
County Commis 6.ers
Teresaaxlrr�,:::, .`
Deputy, 'Ckerk;
NEIGHBORHOOD STABILIZATION PROGRAM 3
AMENDMENT NO.1 TO DEVELOPER AGREEMENT BETWEEN COLLIER
COUNTY AND HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
CFDA: 14.218
THIS AMENDMENT, made and entered into on this, ; ,!',' ,day of January 2013, to the
subject agreement shall -be -by -and between the parties to the original Agreement, Habitat
for Humanity of Collier County, Inc, EIN 59-1834379, (dib/a/ Habitat for Humanity),
authorized to do business in the State of Florida, whose business address is 11145
Tamiami Trail E Naples FL 34113, (hereinafter called the "Developer") and Collier
County, a political subdivision of the State of Florida, Collier County, Naples (hereinafter
called the "County").
Statement of Understanding
RE: NEIGHBORHOOD STABILIZATION PROGRAM B-11UN-12-0003
In order to continue the services provided for in the original Agreement document
referenced above, the parties agree to amend the Agreement as follows:
Words Shue! Through are deleted; Words Underlined are added:
(Dollar amounts have original underlines)
WITNESSETH:
EXHIBIT A. Project Description
A. GENERAL
Developer will be provided NSP -3 Rinds in the amount of Three Million Four
Hundred Ninety Five Thousand Seven Hundred Forty Nine and 00/100 Dollars
($3,495,749). Such funds will be used to acquire and land bank eligible properties in
the Grantees eligible target areas and to pay associated developer fees.
B. ELIGIBLE TARGET AREAS
Properties shall only be acquired in the target areas approved by the GRANTEE and
described in the GRANTEE's NSP -3 action plan. Specifically, DEVELOPER may
acquire properties in any of the following target areas:
Target Area One — Golden Gate City HUD Neighborhood ID 1108764)
Census Tract 0104.10
o GeoID 1202192301263000104 IOU I
o GeoID 1202192301263000104IOU2
o GeoID 120219230126300010410U3
r • • •RAW••• •�•�
AII
F= R NOW,
\ I A
• Census Tract 0104.19
o GeoID 12021010419
• Census Tract 0104.20
o GeoID 12021010420
--.......__ --------- _.._......_ ..._....Cansusiiacl-Ol(4:4- ----
o GeoID 12021923012630001041101
o GeoID 12021923012630001041102
o GeoID 120219230126300010411U3
o GeolD 120219230126300010411R3
o GeoID 120219230126300010411 RI
Target Area Two — East Naples Bayshore Gateway CRA (HUD Nei jahborhood ID
3981140
• Census Tract 0107.01
o GeoID 120219230199999010701U4
o GeoID 12021923019999901070101
o GeoID 120219230199999010701U2
o GeoID 120219230199999010701 U3
o Geo1D 120219230199999010701112
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seals on the date and year
first above written:...
ATTES' '-
Dwight E. Brock, Clete: of Courts
B
0EALi*,t St 8% to Cha iram
1 e
FirstAVitness
t k/uo ) d'k
TType/print witness nameT
,,Second Witn ss
TType/print witness nameT
COUNTY COMMISSIONERS
RUNTY✓FLORIDA
By: V
Geoff a A. r er, Esq.
Chairwoman
Habitat for Humanity of Collier County, Inc.
A Florida not -for -pro -fit corporation
By:'� _
Print: / ,^
Title: C,�
Approved as to form and legal sufficiency:
Jeru» er B. White y
Assistant County Attorney�� ����
AMENDMENT NO.2 TO AGREEMENT FOR THE
NEIGHBORHOOD STABILIZATION PROGRAM 3
CFDA: 14.218
DEVELOPER AGREEMENT BETWEEN
COLLIER COUNTY
AND
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
(NSP -3)
THIS AMENDMENT is made and entered into on this 0, day of 2013, by and between
Collier County, a political subdivision of the State of Florida, having its principal office at 3299
Tainiami Trail East, Naples, Florida 34112 (hereinafter called the "GRANTEE"), and Habitat for
Humanity of Collier County, Inc., a private not -fox -profit corporation, existing under the laws of the
State of Florida, having its principal office at 11145 Tamiami Trail East, Naples, Florida 34113
(hereinafter called the "DEVELOPER") to undertake the Neighborhood Stabilization Program ("NSP -
3") as approved by the Collier County Board of County Commissioners.
Statement of Understanding
RE: Neighborhood Stabilization Program 3 B-11UN-12-0003
In order to continue the services provided for in the original Agreement document referenced above,
the Developer agrees to amend the Agreement as follows:
Words Struek Through are deleted.; Words Underlined are added:
(Dollar amounts have original underlines)
WITNESSETH:
11. Terms and Conditions of the Funding
B. Use of Funds - NSP -3 funds obligated under this agreement may be used as follows:
2. Eligible Activities - Funds may be used for the NSP -3 eligible activities that are checked below.
The number of properties listed is a minimu &gal and is not intended to provide a limit on the
number of properties that may be acquired through this Agreement, as funding permits:
® Acquisition 30 2-7 abandoned or foreclosed
singe family properties
❑
Rehabilitation/ reconstruction # acquired abandoned or
foreclosed
❑ New construction # vacant properties
® Land Banking
5 vacant properties
Demolition As needed and approved by the
Cour.
3. Eligible Properties -- Properties must meet the following conditions to be considered
eligible under this Agreement:
d. Must otherwise be in suitable locations for marketing and resale to low-, and
moderate-, and middle income homebuyers.
V. Disbursement of Funds
IN WITNESS WHEREOF, the Grantee and the Developer, have each, respectively, by an authorized
person or agent, hereunder set their hands and seals on the date and year first above written.
ATTEST:
Dwight E. Brock, Clerk of Courts
By:
Date tri n.;
k
'`-
,,/First W'tness
TTyp.e/prjnt witness name -l'
Second Witness
zvv
TType/print witness nameT
BOARD OF
Chairwoman
'Y COMMISSIONERS
, FLORIDA
, Esq.
Habitat for Humanity of Collier County, Inc.
A Florida not-for-profit corporation
By:
Ni k J. Kouloheras
Executive Vice President
Approved as to form and legal sufficiency:
Jewli'er B. White
Assistant County Attorney ,,,j
MEMORANDUM
Date: July 17, 2013
To: Geoffrey Magon, Grants Coordinator
Housing, Human & Veteran Services Department
From: Teresa Cannon, Deputy Clerk
Minutes and Records Department
Re: NSP 3 Amendment to Developer Agreement w/Habitat for
Humanity
Attached for your records is a copy of the document referenced above, (Item #16D1)
approved by the Board of County Commissioners on Tuesday, July 9, 2013.
The Minutes and Record's Department will hold the original in the Board's
Official Records.
If you have any questions, please contact me at 252-8411.
Thank you.
Attachment
NEIGHBORHOOD STABILIZATION PROGRAM 3
AMENDMENT NO.3 TO DEVELOPER AGREEMENT BETWEEN COLLIER
COUNTY AND HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
CFDA: 14.218
A
THIS AMENDMENT, made and entered into on this day of July, to the subject
agreement shall be by and between the parties to the original Agreement, Habitat for
Humanity of Collier County, Inc, ETN 59-1834379, (d/b/a/ Habitat for Humanity),
authorized to do business in the State of Florida, whose business address is 11145
Tamiami Trail E Naples FL 34113, (hereinafter called the "Developer") and Collier
County, a political subdivision of the State of Florida, Collier County, Naples (hereinafter
called the "County").
Statement of Understanding
RE: NEIGHBORHOOD STABILIZATION PROGRAM B -I IUN-12-0003
In order to continue the services provided for in the original Agreement document
referenced above, the parties agree to amend the Agreement as follows:
Words StruefThrough are deleted; Words Underlined are added:
(Dollar amounts have original underlines)
WI TN ESS ET 14:
ll. Terms and Conditions of the Funding
A. Funding Amount -- NSF -3 Funds in the amount of Three Million Four Hundred
Ninety Five Thousand Seven Hundred Forty Nine and 00/100 Dollars$3 495 749)
are obligated for use in compliance with this agreement. The County will require
Three Hundred Eighty -Eight Thousand and 00/100 Dollars ($388,009) of the original
allocation to be returned to the County y Habitat for Humanity from the proceeds of
sale of NSF3 properties. The County will award the program income generated from
the return of sales proceeds in the amount of Three Hundred Eighty -Eight Thousand
and 00/100 Dollars ($388,000) to Habitat for Humanity to continue to carry out the
NSF3 program_as required by this agreement. In addition up to Forty Thousand and
00/100 Dollars ($40,000) are obligated from NSP1 for the purpose of pang
developer fees associated with this amendment as reflected in the budget in Exhibit
B.
2. Approved budget — The approved budget is attached to this agreement as
Exhibit B. It is understood and agreed that funds will be used according to the
approved budget. It is understood and agreed that funds will be used according
to the approved budget (Exhibit B). Developer has the authority to reallocate
$25,000 per income category, but shall not expend less than the Low Income
Set Aside allocation of $9;942 $1,078,042. Should the Developer determine
that the reallocation is necessary, a prior notification and written approval shall,
be duly signed by the Developer and the Director of HHVS. Reallocations
above $25,000 between income categories will require prior Grantee approval.
E. Sale to Buyers — All units acquired under this agreement shall be sold to eligible
buyers in accordance with the provisions of this section.
Eligible Buyers — Eligible homebuyers must be determined to be income -eligible
in compliance with the limits and funding allocations checked below. It is
understood and agreed that funds will be used according to the approved budget
(Exhibit B). Developer has the authority to reallocate $25,000 per income
category, but shall not expend less than the Low Income Set Aside allocation of
$944,-042 $1,078,042. Should the Developer determine that the reallocation is
necessary, a prior notification and written approval shall be duly signed by the
Developer and the Director of HHVS. Reallocations above $25,000 between
income categories will require prior Grantee approval.
1.
®
Middle Income — 81 % to 120% of Area Median
X00
❑
Income
000
JL118,000
❑
New construction
# vacant properties
❑
Moderate Income — 51% to 80% of Area Median
5 vacant properties
❑
Income
$1,397,707
®
Low Income — less than 50% of Area Median
$9842
Income
$1,078,042
®
Acquisition
34 40 abandoned or foreclosed single-
family properties
❑
Rehabilitation/reconstruction
# acquired abandoned or foreclosed
❑
New construction
# vacant properties
❑
Land Banking
5 vacant properties
❑
Demolition
As needed and approved by the Cou►7t .
V. Disbursement of Funds
A. Project expenses (excluding developer fee) shall be paid based on vouchers for
actual expenses incurred or paid. All such expenses shall be in conformance to the
approved project budget. It is understood and agreed that funds will be used
according to the approved budget (Exhibit B). Developer has the authority to
reallocate $25,000 per income category, but shall not expend less than the Low
Income Set Aside allocation of $971,042 $1,078,042, Should the Developer
determine that the reallocation is necessary, a prior notification and written
approval shall be duly signed by the Developer and the Director of HHVS.
Reallocations above $25,000 between income categories will require prior Grantee
To ensure compliance with the NSP LH25 Requirement, DEVELOPER shall ensure that
One Million Seventy -Eight Thousand Forty Two and 00/100 Dollars (1,078,042) Nine
Hundred Seventy e=fhet Forty ellat-s-($97-1;84-2) be expended
to comply with the LH25 Requirement,
EXHIBIT A-2. Disbursement
GENERAL
Developer shall invest its own funds to complete the rehabilitation or development of the
properties associated with this Agreement thereby assuming risk associated with the
project, To compensate Developer for such risk, and for providing NSP -related goods
and services, such as, but not necessarily limited to, residential rehabilitation, eligible
buyer identification, and final disposition, Developer shall be paid a developer fee.
In addition to payment of developer fees, funding under this Agreement may be used for
the acquisition of eligible properties.
AMOUNT
Grantee shall pay Developer a Ten Thousand and 00/100 Dollars ($10,000) developer fee
for each of the properties acquired through this Agreement. The maximum combined
developer fee paid by Grantee to Developer through this Agreement shall be Two
Hundred Seventy Thousand and 00/100 Dollars ($270,000) from NSP3 fluids, and Forty
Thousand ($40,000) from NSP1 fiends for a total of Three Hundred Ten Thousand and
00/100 Dollars ($310,000); 04s -these amounts represents a cumulative of developer fees
paid for each of the properties acquired through this Agreement.
Grantee shall reimburse Developer a maximum One Hundred Fifty Thousand and 00/100
Dollars ($150,000) for each property acquired through this Agreement, ,,,�'ess a highef
however, such reimbursed amount may not
exceed the actual cost of acquisition. The maximum combined reimbursement paid by
Grantee to Developer through this Agreement shall be Three Million Two Hundred
Twenty Five Thousand Seven Hundred Forty Nine and 00/100 Dollars ($3,225,749);
however the Developer shall be awarded an additional Three Hundred Eighty -Eight
Thousand and 00/100 Dollars ($388,000) from the program income generated b, the
NSP3 ,grant. This awarded amount is generated from the proceeds of the sale of NSP3
property having been originally Tally been returned to the County. The awarded fluids will be
used to fund additional reimbursement to the Developer for the actual cost of acquisition
This amount represents a cumulative of reimbursements paid for each of the properties
acquired through this agreement.
EXHIBIT B. Budget
GENERAL
Developer will be provided NSP -3 funding by the Grantee for the purpose of acquiring
eligible properties for final disposition to NSP -eligible persons or families, including
payment of developer fees. E./
approval.
1, The DEVELOPER shall retain any net proceeds of sales, after the payment of all
closing costs and approved developer fee, under this contract, and shall comply
with the following (as checked):
® The DEVELOPER may reuse such net proceeds of sale for NSP -3 -eligible
activities..
❑ The DEVELOPER shall return the net proceeds of each sale to the
GRANTEE at each closing.
® The DEVELOPER shall return $388,000, upon the sale of NSP3 properties
to the GRANTEE no later than December 31 2013 Proceeds to be
returned from the sale of property are upon receipt by the Count t}� o be
considered Program Income, The Program Income shall be returned into
the NSP 3 program, at which point the DEVELOPER shall be awarded the
entirety of the program income for acquisition of additional NSP3
property.
EXHIBIT A. Project Description
A. GENERAL
Developer will be provided NSP -3 funds in the amount of Three Million Four Hundred
Ninety Five Thousand Seven Hundred. Forty Nine and 00/100 Dollars ($3,495,749).
Such funds will be used to acquire and land bank eligible properties in the Grantees
eligible target areas and to pay associated developer fees.
The Developer shall be required to return to the County an amount of Three Hundred
Eighty -Eight Thousand and 00/100 Dollars ($388,000) from the sale of NSP3 properties
by December 31, 2013. Such proceeds frorn the sale of property by the Developer shall
upon receipt by the County be considered Program Income. Proceeds received from the
Developer will be returned back into Collier County's NSP3 program and be considered
program income upon receipt. The Developer will be awarded the $388,000 in program
income for the purpose of acquiring additional properties for the NSP3 program
E. ELIGIBLE INCOME LEVELS OF BUYERS
NSP -assisted property subject to the Agreement shall be used with respect to individuals
and families whose income does not exceed 120 percent of area median income.
However, not less than twenty-five (25) percent of the funds expended by Grantee in
acquiring the properties subject to this Agreement shall be used to house individuals or
families whose income do not exceed 50 percent of the area median income ("LH25
Requirement").
0
BUDGET
Grantee shall pay Developer a Ten Thousand and 00/100 Dollars ($10,000) developer fee
for each of the properties acquired through this Agreement. The maximum combined
developer fee paid by Grantee to Developer through this Agreement shall be Two
Hundred Seveaty Thousand 00/100 Dpligg ($270,000) Three Hundred Ten Thousand
00/100 Dollars ($310,000); this amount represents a cumulative of developer fees paid
for each of the properties acquired through this Agreement.
Grantee shall reimburse Developer a maximum One Hundred Fifty Thousand and 00/100
Dollars ($150,000) for each property acquired through this Agreement, unless -a-h.:gher
ametint is-appreved-in. writirtg-b.-6ttee however, such reimbursed amount may not
exceed the actual cost of acquisition, The maximum combined reimbursement paid by
Grantee to Developer through this Agreement shall be Three Million Two Hundred
Twenty Five Thousand Seven Hundred Forty Nine and 00/100 Dollars ($3,225,749);
however the Developer shall be awarded an additional Three Hundred Eighty -Eight
Thousand and 00/100 Dollars ($388,000) from the program income generated by the
NSP3 grant. This awarded amount is generated from the proceeds of the sale of NSP3
property having been originally been returned to the County. The awarded funds will be
used to fund additional reimbursement to the Developer for the actual cost of acquisition
This amount represents a cumulative of reimbursements paid for each of the properties
acquired through this agreement.
Line Item
Amount
Original Award Ac uisition & Developer Fee
$3,495,749.00
NSP3 Program Income awarded (Generated from proceeds
$388,000.00
returned to the Count
Additional Develo gr Fee's for NSP3 activities l2aid by NSP 1
40 000.00
Final Total Awarded to Habitat 1
$3,923,749.00
INCOME TARGETING
Funds associated with this Agreement shall be expended spent within the following
income targets.
Line Item
Amount
County Administration
$388,416
Habitat for Humanity Developer .Fee
$270,000
Additional HFH Develo er Fee
149.1-00-0
Low -Income Set Aside (50% AMI)
$974;842
j1 07&042
51% AMI - 80% AMI
$-584A7
1 397 707
81% AM_ 1- 120% AMI
$750,000
81% AMI - 120% AMT (PI Generated
388 000
TO'T'AL9$4,312,165
ot,c
It is understood and agreed that funds will be. used according to the approved budget.
Developer has the authority to reallocate $25,000 per income category, but shall not
expend less than the Low Income Set Aside allocation of $1,078,042. Should the
Developer determine that the reallocation is necessary, a prior notification and written
approval shall be duly signed by the Developer and the Director of I-IHVS. Reallocations
above $25,000 between income categories will require prior Grantee approval.
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seals on the date and year
first above written.
ATTEST:
Dwi A.:B. 3Tbr*, 'Clerlc of COUrts
Dated:t
signature `only
First Witness
TType/print witness
Second
nt witness name
QPG0
— P'
BOARD OF COUNTY COMMISSIONERS
COLLIE ' UNTY, FLORIDA
By:
Geor 'a i er, Esq. Chairwoman.
Habitat for Humanity of Collier County, Inc
A Florida not-for-profit corporation
By:�
MME—W-4 .
Approved as to form and legality:
Jennifer A. Belpedio
Assistant County Attorney
CC11` j
NEIGHBORHOOD STABILIZATION PROGRAM 3
AMENDMENT NO.4 TO DEVELOPER AGREEMENT BETWEEN COLLIER
COUNTY AND HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
CFDA: 14.218
THIS AMENDMENT, made and entered into on this 4 -1 -'day of MoLkc,�% 2014 to the
subject agreement shall be by and between the parties to the original Agreement, Habitat
for Humanity of Collier County, Inc, EIN 59-1834379, (d/b/a/ Habitat for Humanity),
authorized to do business in the State of Florida, whose business address is 11145
Tamiami Trail E Naples FL 34113, (hereinafter called the "Developer") and Collier
County, a political subdivision of the State of Florida, Collier County, Naples (hereinafter
called the "County" or "Grantee").
Statement of Understanding
RE: NEIGHBORHOOD STABILIZATION PROGRAM B-1 IUN-12-0003
In order to continue the services provided for in the original Agreement document
referenced above, the parties agree to amend the Agreement as follows:
Words Struel Through are deleted; Words Underlined are added:
(Dollar amounts have original underlines)
WITNESSETH:
11. Terms and Conditions of the Funding
D. Deadlines — Timely completion of the work specified in this agreement is an
integral and essential part of performance. The NSP -3 fluids are subject to Federal
deadlines and failure to comply could result in the loss of the .Federal funds. By the
acceptance and execution of this agreement, it is understood and agreed by the
DEVELOPER that the PROJECT will be completed as expeditiously as possible
and that the DEVELOPER will make every effort to ensure that the project will
proceed and will not be delayed. Failure to meet these deadlines can result in
cancellation of this contract and the revocation of NSP -3 fiords.
1. Project Expenditure Deadlines -- All eet:-ae—`,ities and all explenditweg-e€
NSP 3 Rinds fatist be eempleted byarch—1 l201,11 HUD requires that an
amount equal to 100% of the original grant amoiuit must be expended by
March 11,_ 2014 The llevelo�er must assist the County in meeting the
expenditure deadline as follows: if eheeked the additionalir2teriiTiAead-knes
P
a eRditttres: 3
® Amount equal to 50% of NSP -3 original 03/11/2013
grant award €wilds expended end draym
by the County
1IPage
® Amount equal to 100% of NSP -3 03/11/2014
orip,inal grant award PwKk expended afid
d}aym by the County
® PROJECT activities completed Prior to Project
Closeout
Ill, Project Requirements
The DEVELOPER agrees to comply with all requirements of the NSP -3 as stated in the
NSP -3 Notice and CDBG regulations, including but not limited to the following:
A, NSP -3 Eligible Use, CDBG National Objective and Eligible Activities — The
DEVELOPER will ensure and document that its NSP -3 activities meet LMMI
national objective, eligible use, allowable cost, and eligible activity requirements of
the NSP -3 Notices & CDBG Regulations. The DEVELOPER will ensure that any
expenditure of NSP -3 fluids will be in compliance with the requirements, and
acknowledges that NSP -3 funds will only be provided as reimbursement for
eligible costs incurred, including actual expenditures or invoices for work
completed. The DEVELOPER will ensure that any Land Banking activities will
follow the Land Bank Plan as described in "Exhibit C"
Signature page to Follow
21P age
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seats on the date and year
first above written.
ATTEST:
Dwight E. Brock; C16rk of Courts
Bye.
Dated; j —I 4��W
'(SEA14est as to hairman s.
signature only.
First Witness
Second
BOARD OF COUNTY COMMISSIONERS
COLLIER QOUNTY, FLORIDA
B
(Tom Henning,
Habitat for Humanity of Collier County, Inc.
A Florida not-for-profit corporation
By:
jit witness arne I
Title:11
-/4l - = ,
Type/print witness name
Approved as to form and legality:
Jennifer A. Belpedio�3
Assistant County Attorney �LA
3
C
EXHIBIT C. Land Bank Plan
Neighborhood Stabilization Program
Land Bank Report and Recommendations
Collier County, Florida
October 25, 2013
Report by Gladys Schneider
TDA TA NSP3-018-1
Contents
Overview. . 5
Current Status 5
Summaryof Recommendations.,.,,..,,1.......................... .. ..................................... 6
Land Bank Plan Guidelines _..6
Goalof the Land Bank.................................................................................................. ..... 6
National Objectives._.__ . 6
Land Bank Oversight. . 7
Ten Year Limitation on NSP Land Bank Properties,,..., .... . 7
Side Lot Disposition ...,_._ .............................. 7
Future acquisition of properties for the Land Bank...................................................................................... 7
Responsibilities and Requirements. . 7
APPENDIX I. .9
APPENDIX 2. � .,,.... 9
APPENDIX3 .................. .... ............ ........... .... .......... ................. ..............................«.___..................... •..... X10
41Paye
Overview
This repoii presents the results of technical assistance provided to Collier Counjy fit the
consideration of forming an NSP Land Bank in conjunction with Habitat for Humanityof Collier
Count Habitat). Several discussions were held with County Staff and habitat representatives,
and both provided documents for the review of jand bank policies developer agreements. and
current land bank inventory. _ This j
_gp
gil-p o idesL information on the current situation.
mOlrum�tldatlQ.;,,.Ana,pLQppS d_land bank plan._guidelines, A.pmndices__provide_the_land_bank
in entoiy in the format that would be included in the Land Bank Plan a summary of the Collier
County and Habitat for Humanity NSP plans and agreements and a summary of NSP regulatory
citations re ag rding lend batilcs.
Current Status
Collier County authorized the formation and operation of a land bank in its Neighborhood
Stabilization Program.(NSP). Habitat curreirtft holdstitle to vacant residential lots that were
purchased witli Collier County _NSP3 fiends As the program near completion the County and
Habitat need to develop specific program policies to carry out the Land Bank strategy that was
authorized in the NSP program The inventories of properties proposed for the NSP Land Dank
are included in Appendix 1.
Collier County's NSP3 Action Plan provide for the formation and operation of a land bank
(Appendix._•) If enacted the Courcy would adopt a Land Bank Plan and enter into agreement
with Habitat for Humanity to implement the program..Generally speaking; the Land Bank Plan is
designed to carry out the goals of the Neighborhood Stabilization Program (NSP) with the
purpose of removing blight providing_ affordable housing and promoting redevelopment and
revitalization The Housing and Economic Recovery Act of 2008 (Division B. Title I1I) is the
authorizing_ legislation for land banks as an eligible use of NSP funding with certain limitations.
Under this legislation, a Land Bank is defined as:
Land bank: A land bank is a governmental or nongovernmental nonproftl entity
established at least in part, to assemble, orat ►mama e _�rkrd dispose a va (i land
for the 1rurp_ose of stabilizing neighborhoods and encouraging re -use or redevelopmentof
urban property For the purposes of NSP a land bank will operate in a spedkc de fned
geographic area. It will purchase propertles that have been -foreclosed upon and maintain.
assemble facilitate redevelopment of market and dirpose of the land -banked properties. If
ille land bank is ct govenirnental entity,it 't may also maintain Lorealosed property that it
does not own provided it charges the owner of the propeiYy the full cost of the .service or -
places a lien on the property for the full cost of the service. (see Appendix 3 for >rmthet
e u cuou- background on land batiks)
A Land Bank Plan -is an NSPeq
ruirement.if tete Count intends to close out its NSP grant and
there are NSP assisted properties that have not yet been obligated to an end use that meets one of
the NSP applicable National Objectives By adopting�a Land Bank Plan the County will be able
to close out its NSP grants if other close-out rec uirements are met. A Land Bank Plan Nvill
provide guidance to both parties to ensure that program. regi irements are met and the proposed
schedule has proper oversight,
Since Habitat already holds title to the NSP properties the NSP3 Action Plan includes.o Land
Bank 5lrntegy, thele is.nhcadxa framework flit moving fi�rward. Habitat will administer the Land
Bank and report to theCount on. the actiyities knd.disposition of the propct�ties. The Land Bank
Plan addresses the NSP3 properties and defines the specific.end use for their disposition and the
61Page
national objective that will be met. The Land Bankug idelines can be included in the Developer
Agreements -with Habitat. or by a separate W•eemen .
Summary of Recommendations
The Coun should proceed with a Land Bank Plan and Agreement with Habitat for H imanityto
guide the completion of the 4 remaining properties that would be included in the land bank
program. The County will not need to revise its NSP3 Action Plan as it included Eligible Use C.
Land Bank, The Developer Agreements between Habitat and the County authorize land banking
activities. There are four NSP3 parcels -_ all single family residential lots. Habitat intends to
complete ie NSP3 homes by the end of 2014, These schedules are based upon buyer demand
and market conditions. The relatively short anticipated timeframe giyes.the County some
flexi 'lits it could continue, to oversee the eventual completion of the homes tinder its current
aa,eements, but would not be able to close out their NSP grants.
The adoption of a Land Batik Plan and Agreement with Habitat will enable the County to close
out their NSP grants if other requirements are complete. A Land Bank Plan would provide a
more formal understanding of what is to be completed and byIw nen. There would be a basis for
extending the development timetiame if needed, since ten years holding time would be available
from the date of grant closeout. The Collier Cougty urogram has the benefit of fewer scenarios
than other NSP land banks in that all of the properties are similar and will be obligated for the
development of affordable housing. Side Lots, rezoning, re -platting, or other complexities are
absent from this situation resulting in a streamlined approach that wiltgquire a uiininiunl_of
administrative procedures. T et_e was some mention that some of the lots may turn out to be
wetlands and unbuildable, That Vossibility is addressed in the guideliries suggested, Finally, the
County has a good working relationship with Habitat and the Land Bank Plan would be an
extension of that relationship to mutitai benefit.
Land Bank Plan Guidelines
The following guidelines are intended to provide direction for the implementation of tine NSP3
pro rag rn requirements as part of the agreement established between Collier County and Habitat
for Humanity of Collier. It is recommended that these guidelines be included as an amendment to
the effective Developer Agreement. between Collier Counjy and Habitat for Humanity.
Goal of the Land Bank
Theog al of the Land Bank is to acquire maintain and eventually dispose of NSP assisted
pro ep rhes within a desi ng ated time frame to stabilize neighborhoods in specified geographic
areas in accordance with Neighborhood, Stabilization Program rules and regulations.
National Objectives
The acquisition, rehabilitation, demolition and reconstruction of real _pt•o Le are eligible
activities with NSP funds, but the end use must also meet a National objective. Acquisition and
demolition alone do not meet a national objeclive. By including an NSP procrty in a Land
Bank, a period often years holding is allowed tinder (lie program rules before a national objective
must be met. When all NSP. rg ant activities have been completed. and rettiainin&parcels that
have not vet met a national objective are placed in a•Land I3p the ranig-q m,ay_close out their
6 1 P a g e
=rant wiih..HUD_ This relieves the Grantee from ongoitt� Brants administration responsibilities,
even tlLoggh there Wray still be program income ret u_tting b the Grantee.
The following_ National Objectives are appropriate for the Collier County NSP and Bank.
Housinp-Activities LMMH Providingor i ni oving permanent residential structures
that will be serving individuals or households whose dross annual income does not.
exceed 120% of the area median income adjusted for family size and as published
annually by HUD Examples include acquisition rehabilitation, demolition and
reconstruction of affordable hones.
Area Benefits LMMH Activities that benefit all of the residents of a primarily
residential area in which at least 51 % of the residents have incomes at or below 120% of
the area median income... Examples include the donation or sale of a parcel for open
space or conservation,
Land Bank Oversight
The.Coll ier County Department of Housing Human and Veteran Services will have the
responsibility to ►nonitor the implementation of the Land Bank Plan Habitat for Humanity of
Collier County, inc will be responsible for the maintenance and disposition of the properties,
Ten Year Limitation on NSP Land Bank Properties
All land bank properties must meet a national objective within ten years of the closeout date of
the applicable NSP I or NSP3 grant. A4y properties that have not met a national objective w�_ _
immediately be used for CDBG purk oses The NSP Land Bank Properties will revert ten ears
from closeout to Collier County if theme have not met a National ObJective.
Side Lot Disposition
The Collier County C.and Bank_�'oarain does not foresee the sale donation or other transfer of
land bank properties to adiacelit propert owners.
Future acquisition of properties for the Land Banic
The Collier Counter and Bank pl-ogram does not.foresee increasing the inventor -of non -NSP
properties in the NSP Land Bank.
Responsibilities and Requirements
I. Habitat is responsible for all. maintenance and expenses associated with the stewardship
of the land bank properties.
2. 13abitat is responsible for all title and transfer expenses associated with the disposition of
the land bank pro er les.
3. Hal}itaI will construct homes on bu 11dable.pro i les by the date specified. Purchasers
will be NSP eligible beneficiaries.
4. A minimum of 25% of the NSP funds eX-p— ded will serve households with incomes at or
Wow 50% of the area medifu} income _er Developer Agreenic►its.
71Page
5. NSP3 finds can be used for acquisition and demolition, ReLconstruction and all other
development, maintenance and transfer costs are the responsibility of Habitat.
G. Habitat is responsible for reporting to the County oit.land bank activities and disposition
no less than once annually.
7. Habitat is entitled to a set fee of $10000 per unit as a developer fee for NSP3 homes.
This fee is„paid half upon acquisition of the foreclosed property and half upon completion
of the home and sale to an eligible beneficiary.
8. The feasibility for eventual development of the properties should be considered to
determine if all properties are suitable for residential construction. If not, the properties
shall be desi nated,as open space or conserval ion and Habitat may negotiate a transfer to
either a public agency, a nonprofit organization or may retain title along with full
maintenance responsibilities. In order to meet the Area Benefit rule. (LMMA), the use
trust benefit all the residents of a primarily residential neighborhood in which at least
51% of the residents have incomes at or below 120% of the area median income.
Designation of the non -buildable pro erdes as open space or conservation is an
appropriate zea benefit use.
8 1 P a g e
r�
APPENDIX I
Land Bank Inventory
Parcel
ID#
NSP Program
Location/Address
Status
End Use and
NationalObieetive
Disposition
NSP3
4476 20 St S_ ty
acan
lot
—Single Fkijiily
Ownership
L( MMH)
_Date
12/31/2014
NSP3
_
4589 30` Ave
S.W
V cant
lot
Single Family
Ownership
LMMH
12/31/2014
NSP3
1948 45 Ter. r. __
S.W.
Vacant
lot
Sin le family
Ownership
LMMH
_
12/31/2014
_.
NSP3
3018 52" St, S.W
Vacant
lot
Single Fanil,
Ownership
LM MH
_
12/31/2014
APPENDIX 2
Land Banking Authority
Summary of Collier County NSP3 Plan and Developer Agreement with Habitat for
Humanity
NSP3 Action Plan, Collier County
M_picpLa
r COEM
3 Action Plan includes a Land Bank Strate with a budget of $388AM
pring iln�lemented through a developer agreement with Habitat for
f nty. Habitat has purchased four blightedpropertiesunder the land bank
le_abitat and maintenance is beingprovided at Habitat's own expense.
lished and rite four lots are vacant Habitat intends to have new homes
.eeobjective by December•gf 2014. Habitat and the Coturty are working
Logether under a Developer Agreement. As such, Habitat holds title to the properties that were
acquired by the County, cleared of blighted structures before deeding them to Habitat.
NSP3 Developer Agreement, Collier County and IIabitat for Humanity of Collier County
The initial a reenLpt was executed on 4-24-12 for $3 495,749 for 27 homes. Under this
agreement, Habitat was responsible for the acquisition process as well as demolition. There were
3 amendments to_the Ageeement.
Other rovisions of the Agreement include:
- The maximum NSP reunbursemeni per. unit is , 150,000
- 25% of the funding received would be.allocated to Meeting the low income set-aside
Habitat_would receive a $lO,UUU develo�r lee per writ, 5t1% a al>I�on acquisition
and 50 -/..gable upon sale tq an elide btryer
The_deyeloner is responsiblefor ac 30 units and conductiiig
demolition as needed
9jpage
- Habitat may retain all project_proceeds
- Lonp, term affordability is the minimum provided by_tlp NSP statute
- Amendment 1 (1 /8/13) revised the target areas
- Amendment 2 (2/12/13) increased units from 27 to 30, added approximately 5 units to
Land Bankin"nd demolition as needed and added as eligible beneficiary middle
income households.
- Amendment 3 07/9/13) increased units to approximately 34 adjusted theagreement
amount to allow for program income allocations to the Developer,
APPENDIX 3
NSP Statutory and Implementing Citations
NSP Land Bank Background information (Unified NSP Notice- 75 FR 64322)
NSP Delinition of Land Bank
A land bank is a governmental or nongovernmental nonprofit entity established at least in part, to
assemble, teutporarily manage. and dispose of vacant land for the purpose of stabilizing
neieltborhoods and encouraging re -use or_ redevelopment of urban property. For the purposes of
the NSP a land bank will operate in a specific defined geographic area. 1t will purchase
properties that have been abandoned or foreclosed upon and maintain assemble, facilitate
redevelopment of market and dispose of the land -banked properties. If the land bank is a
governmental entity, it may also maintain abandoned or foreclosed property that it does not own
provided it charges the owner of the property the full cost of the service or places a lien on the
property for the ful l cost of the service,
Eli-eible Uses (Mitshm and Economic Recovery Act) and NSP Closeout Notice (Nov 27, 2012
288 FR 70799)
• Establish financing mechanisms for purchase and redevelopment of foreclosed upon
homes and residential properties, ino &njz such mechanisms as soft -seconds loan loss
reserves,.and shared -equity loans for low- and moderate -income homebuyers
• Purchase and rehabilitate homes and residential properties that have been abandoned or
foreclosed upon to sell, rent or redevelop such homes and pro erties
• Establish land banks for homes and residential Properties that have been foreclosed
upon
• I?emolish blighted structures
• Redevelop demolished or vacant properties
Eligible Activities (CDBG)
The NSP fiords used for land barikina must correlate with an ell iba le activity under 24 CFR
570.201(x) Acquisition & (_b) Disposition;
A. Acquisition in whole or impart by the recipient, or other pblic or private nonprofit
entity, ...purchase, long-term lease, donation, or otherwise, of. real property
(including air rights, water rights rights-of-way, easements,_ acrd outer interests
therein) for any public purpose, sub'ect to the limitations of Sec. 510.207.
B, D_ jSposition_thrMh..sale, lease, donation, or otherwise, of any realproperty �cciuired
with CDBG fiords or its retention for puUlic_pur osp 'es, including reasonable costs of
temporarily _managing suci— propegy or property acquired under urban renewal
wided drat the proceeds from any_ suchdisposition shall be ogram income
subject to the requirements set forth in Sec. 570,504. (Temporari!y in nagirg
101Page Q
(• T
inchr(Ies maintenance assembly facilitating the redeveloDrnent of, and marketing of
land banked properties NSP funds may be used for basic, reasonable maintenance
intended to stabilize the property_.)
NSP National Obieefives
Each NSP activity must meet a National Obiective, NSP national objectives include liousulg
activities (LMMH), area benefit activities (LMMM and limited clientele activities LMMC) The
Closeout Notice added one more- the jobs national objective (LMMJ). Since all of Collier
County's land bank parcels are residential. the LMMH and possibly the LMMA would ke
applicable national objectives.
NSP Closeout Notice -Federal Register% November 27 2012_(288 FR 70799
The Notice describes closeout m lrements and additional regulations that apply y to grantees
receiving grants under the three rounds of funding under the Neighborhood Stabilization
Program. Land Banks are addressed in several parts ofthe Closeout Notice,
1.A.4,c,(iii) The Closeout Agreement between the grantee and HUD must include "a list of real
ro erty held in an NSRassisted land bank", and (iv) if the g_r•atitee has assisted a land bank a
plan detailing how the land bank will meet the 10eat rmaximum holdin�requiremenf of Section
Il.E,2.d of the Unified NSP Notice and Appendix I Section E 2 d of the NSP2 NOPA
IA.2. The Unified NSP Notice was amended to requirethat grantees report at least annually on
the disposition of land bank properties.
I.A.2. The start date for-te ten year maximum holding period will begin the date of the grant
closeout to meet an eligible redevelopment of the_property in accordance with NSP requirements.The ant e_is required to obligate or otherwise commit the property for a specific use auo op ming
neighborhood stabilization.
II.A.2. UfUD will pro iv de further direction in reporting and tracking_(subsequent webinars have
provided guidance),
U.A.2(2)(b). Dis osition of Land -Bank Propertv._Properties in a land bank will be considered
obligated for redevelopment if the proms • is: —T
(1) Owner a local .government or nonprofit entity and identified under.a Consolidated
Plan approved by HUD for a CDBG eligible public improvement such as parks, open
space or flood control
(2) Owned by a community land trust to create affordable housing;
(3) Transferred to and committed for any other use in._the annual Actiotr Plan. subject to all
CDBG regulations and no longer part of the NSP ro ram.
(4) Designated for affordable housing in accordance with HERA and under development by
an eligible development entity which as control of the site andhas expended
predevelopment funds;
(5) tnmktded m a redevelopment plan that has been approved by the local govcLnigg body,
I1.A,2.(2)(c);,Any NSP assisted land bank prolnrties remaining; in the land bank ten years after
the date of rant closeout steal revert entire! to the CDBG Program and must be,immediatel
used to meet a national objective or disposed of in accordance wish CDBG use of real pro ert
re irements at 24 CFR 570.505,
111Page %
r'�
MEMORANDUM
Date: June 27, 2014
To: Geoffrey Magon, Grant Coordinator
Housing, Human & Veteran Services
From: Teresa Cannon, Deputy Clerk
Minutes & Records Department
Re: Amendments #2 and #5 to Developer Agreement with Habitat for
Humanity of Collier County, Inc.
Attached is a copy of the document referenced above, (Item #16135) approved by the
Board of County Commissioners on June 24, 2014.
The original Amendments are being held in the Minutes & Records Department as part of
the Board's Official Records.
If you have any questions, please feel free to contact me at 239-252-8411.
Thank you.
Attachments (2)
NEIGHBORHOOD STABILIZATION PROGRAM 3
AMENDMENT NO.5 TO DEVELOPER AGREEMENT BETWEEN COLLIER
COUNTY AND HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
CFDA: 14.218
+h Zof9-
THIS AMENDMENT, made and entered into on this .2q day of J -d nl t,, to the subject
agreement shall be by and between the parties to the original Agreement, Habitat for
Humanity of Collier County, Inc, EIN 59-1834379, (d/b/a/ Habitat for Humanity),
authorized to do business in the State of Florida, whose business address is 11145
Tamiami Trail E Naples FL 34113, (hereinafter called the "Developer") and Collier
County, a political subdivision of the State of Florida, Collier County, Naples (hereinafter
called the "County" or "Grantee").
Statement of Understanding
RE: NEIGHBORHOOD STABILIZATION PROGRAM B-11UN-12-0003
In order to continue the services provided for in the original Agreement document
referenced above, the parties agree to amend the Agreement as follows:
Words Struel{ Through are deleted; Words Underlined are added:
(Dollar amounts have original underlines)
WITNESSETH:
I. Definitions
2. "Appraisal" means an appraisal which meets the criteria specified in the Uniform
Relocation Assistance and Real Property Acquisition Policies Act ("URA"), as
further defined in 49 CFR 24.103. The NSP Policy Alert entitled "Guidance on
NSP Appraisals: Voluntary Acquisitions March 15, 2012" requires that
acquisition of real property using federal funds is subject to URA and the
additional NSP requirements that an appraisal be completed or updated within 60
days of a final offer made for the property y a grantee for the purpose of
acquisition. Appraisals for the disposition of property are not subject to the 60
day requirement for acquisitions. The Developer may complete appraisals
beyond the 60 days of final offer as previously defined.
5. "Current market appraised value" means the value of a property that is established
through an appraisal made in conformity with either: 1) the appraisal requirement
of the URA at 49 CFR 24.103, or 2) the Uniform Standards of Professional
Appraisal Practice ("USPAP"), or 3) the appraisal requirements of the Federal
Housing Administration ("FHA") or a government sponsored enterprise ("GSE");
1 (Page
9
and the appraisal must be completed or updated within 60 days of final offer made
for the property by a grantee, subrecipient, developer, er indite -l -buyer -.The 60
day requirement does not apply to the disposition of a propeto a final
beneficiary. However, if the anticipated value of the proposed acquisition is
estimated at $25,000 or less, the current market appraised value of the property
may be established by a valuation of the property that is based on a review of
available data and is made by a person the grantee determines is qualified to make
the valuation.
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seals on the date and year
first above written.
ATTEST:
Dwight E. Brock, Clerk of Courts
Qe.
Vjjes
(t asto Chairman's
wt'- U
first Witness
Fyve �v
TType/print witness nameT
Second Witness
10-00A? 0,114
TType/print witness nameT
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
B
Tom Iennmg, Chai
Habitat for Humanity of Collier County, Inc
A Florida not-for-profit corporation
Print: 01A 0
i
Approved as to form and legality:
Jen fifer A. elp
Assistant Countytirney 1 y �\p�
2 1 P a g e LAS
EXHIBIT A. Project Description
F. MAXIMUM SAGES PRICE
If an abandoned or foreclosed -upon home or residential property is purchased,
redeveloped, or otherwise sold to an individual as a primary residence, then such
sale shall be in amount equal to or less than the cost to acquire and redevelop or
rehabilitate such property up to a decent, safe and habitable condition. The
maximum sales price for a property is determined by aggregating all costs of
acquisition, rehabilitation, and redevelopment (including released activity delivery
costs, which generally include, among other things, costs related to the sale of the
property). Note that the maximum sales price may not exceed the current market
value of the unit as established by an appraisal. Note that for disposition neither the
County nor the Developer are required to perform the appraisal in conformance with
the NSP Policy Alert entitled "Guidance on NSP Appraisals: Voluntary Acquisitions
March 15, 2012". The associated guidance is required only when acquiring real
property with federal funds. While the NSP 1 program does not require an appraisal
be done when disposing of property, the County will require the Developer to
perform an appraisal to ensure that the market price is appropriate however this
disposition appraisal is not subject to the NSP Policy Alert entitled "Guidance on
NSP Appraisals: Voluntary Acquisitions" and may be completed beyond the time
period of 60 days.
3 1 P a g e CCA
NEIGHBORHOOD STABILIZATION PROGRAM 3
AMENDMENT NO.6 TO DEVELOPER AGREEMENT BETWEEN COLLIER COUNTY AND
HABITAT FOR HUMANITY OF COLLIER COUNTY, INC.
CFDA: 14.218
THIS AMENDMENT, made and entered into on this /0 day of ply o`��I is by and between the
parties to the Agreement, Habitat for Humanity of Collier County, Inc, EIN 59-1834379, (d/b/a/ Habitat for
Humanity), authorized to do business in the State of Florida, whose business address is 11145 Tamiami Trail E
Naples FL 34113, (hereinafter called the "Developer") and Collier County, a political subdivision of the State of
Florida (hereinafter called the "County"), hereinafter collectively known as the "Parties".
RE: NEIGHBORHOOD STABILIZATION PROGRAM B-1 IUN-12-0003
In order to continue the services provided for in the original Agreement document referenced above, the parties
agree to the following amendments:
Words StrueThrough are deleted; Words Underlined are added:
RECITALS:
WHEREAS, on January 8, 2013, the Parties entered into Neighborhood Stabilization Program 3,
Developer Agreement ("Agreement"); and
WHEREAS, on February 12, 2013, the Parties entered into Amendment 1 to the Agreement to establish
land bank activities; and
WHEREAS, on June 24, 2013, the Parties entered into Amendment 2 to the Agreement to clarify eligible
activity goals and dispursment of funds; and
WHEREAS, on July 9, 2013, the Parties entered into Amendment 3 to the Agreement to adjusted the terms
and conditions of funding and the dispersment of funds; and
WHEREAS, on March 11, 2014, the Parties entered into Amendment 4 to the Agreement to clarified
expenditure deadlines and added the land bank plan, Exhibit C; and
WHEREAS, on June 24- 2014, the Parties entered into Amendment 5 to provide expanded guidance on
NSP appraisal requirements; and
NOW THEREFORE, in consideration of the foregoing Recitals, and other good and valuable
consideration, the Parties agree to modify Exhibit A-1 to the Agreement as follows:
Statement of Understanding
RE: NEIGHBORHOOD STABILIZATION PROGRAM B-11UN-12-0003
11Page
In order to continue the services provided for in the original Agreement document referenced above, the parties
agree to amend the Agreement as follows:
Words ,Strum Through are deleted; Words Underlined are added:
(Dollar amounts have original underlines)
WITNESSETH:
EXHIBIT A-1. Affordability Requirements
GENERAL
HOMEOWNERSHIP: LONG TERM AFFORDABILITY
LONG TERM AVAILABILITY:
FOR DEVELOPER SOLD PROPERTIES
Resale: 24 CFR 92.252(a), (c),(e), and (f)and 92.254
Resale restrictions shall be idemented for every home bumproperty constructed redeveloped or
rehabilitated, in whole or in partwith NSP funds in the form of a development subsidy., A
development subsidy consists of the difference between the cost of producing the unit and the fair
market value of the property. If NSP funds are provided to the property it will be subject to a resale
restriction.If the home buyer determines that it no Ionizer intends to use the property as its principal
residence, resale restrictions require the homebuyer to sell the property to a family that will use the
property as its principal residence and meets the income limits described in the lien and restrictive
covenant on that property. The house must be affordable to a range of new buyers in the target
affordable range. The new buyer must occupy house as principal residence. The remaining_ resale
restrictions apply to new buyer, for the period of affordability.
The original homebuyer is entitled to a fair return on its investment as described below
Lupon the sale
of the property. The fair return will be based on the percentage change in the Consumer Price Index for
2 1 P a g e _ _
All Urban Consumers Owners' Equivalent Rent of Primary Residence category in Table I of the CPI
Detailed Report (the "CPI Index") duringthe period of the homebuyer's ownership Accordingly, the
CPI Index during the month the residence was completed (the month during; which the completion
reports were received by and approved by IHCDA) will be compared to the CPI Index during the
month the original home buyer sells the residence to determine the percentage of the return. The
homebuyer's investment will include any down payment paid by the homebuyer plus M capital
improvements. A capital improvement is any_property enhancement that increases the overall value of
the property, adapts it to new uses or extends its life such as: adding windows insulation a new drive
way, a new furnace a garage bedroom new roof, remodeling kitchen etc Any capital improvement
will be valued based on actual cost as documented by the original homebuyer's receipts. Generally,
replacing worn dated components such as appliances or carpet would not be considered an improvement
that adds value
or adapts it to new uses.
The purchasing family should pay no more than thirty (30%) of its gross family income towards the
principal, interest, taxes and insurance for the property on a monthly basis In certain circumstances
such as a declining housing market where home values are depreciating, the original homebuyer may
not receive a return on his or her investment because the home sold for less or the same price as the
original purchase price and a loss on investment may constitute a fair return.
Resale Example:
Assumption: NSP funds total
development Total Development
Costs (TDC) $120,000 Sale price
based on appraisal $90,000 Principle
reduction $10,000
First Purchase mortgage $80,000
Closing cost assistance $1,600
Amount determining compliance
$120,000
Compliance period 15 years
In the event of a deed in lieu of foreclosure or a foreclosure the lien holder or mortgagee will insure that
that home be sold to a family that will use the proppr1y as its principle residence and meets the income
limits described in the lien and restrictive covenant on the property_
31Page
IN WITNESS WHEREOF, the GRANTEE and DEVELOPER, have each, respectively,
by an authorized person or agent, hereunder set their hands and seals on the date and year
first above written.
ATTEST:;,
Dwight ;:Brod;. of Courts
Bye
Dated:
Attest as to iftn's
signature oniv.
4 1 P a g e
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA
By: /
Tim Nance, Chairman
Habitat for Humanity of Collier County, Inc.
A Florida not-for-profit corporation
By:s�i'
Print:
Title:
Approved as to form and legality:
Jennifer A. Belp 'o
Assistant County'Altomey