The URL can be used to link to this page

#17-7602 (Tindale-Oliver & Associates, Inc.) Contract#17-7602 "Collier County Parks and Recreation Division Master Plan" PROFESSIONAL SERVICES AGREEMENT THIS AGREEMENT is made and entered into this 1 Ilsi‘ day of A134;i , 20 /7 , by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY" or "OWNER") and Tindale-Oliver & Associates, Inc., authorized to do business in the State of Florida, whose business address is 1000 N. Ashley Drive, Suite 400, Tampa, Florida 33602 (hereinafter referred to as the "CONSULTANT" and/or "CONTRACTOR"). WITNESSETH: WHEREAS, the OWNER desires to obtain the professional Master Planning Consulting services of the CONSULTANT concerning Collier County Parks and Recreation Division Master Plan (hereinafter referred to as the "Project"), said services being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows: t #17-7062 Collier County Parks and Recreation Division Master Plan iiii)Consultant:Tindale-Oliver&Associates,In ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to OWNER professional Master Planning Consulting services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the OWNER for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to OWNER. 1.5. CONSULTANT designates Virginia L. Corless, Vice President a qualified licensed professional to serve as the CONSULTANT'S project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating 2 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. to this Agreement. The CONSULTANT agrees that the Project Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without OWNER'S prior written approval, and if so removed must be immediately replaced with a person acceptable to OWNER. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from Owner to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to OWNER. 1.7. The CONSULTANT represents to the OWNER that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the OWNER'S review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119 (including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: 3 #17-7062 Collier County Parks and Recreation Division Master Pia, Consultant:Tindale-Oliver&Associates, In. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 4 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. 0 If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. In the event of any conflicts in these requirements, the CONSULTANT shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of each such conflict. OWNER'S approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project. 1.7.1 The County reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to Consultant's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the County reserves the right to make sole determination regarding deductions. After notification of deficiency, if the Consultant fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the Consultant. The County may also deduct or charge the Consultant for services and/or items necessary to correct the deficiencies directly related to the Consultant's non-performance whether or not the County obtained substitute performance. 1.8. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER'S prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to 5 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. (9-;) comply with the provisions of this paragraph. CONSULTANT shall provide OWNER prompt written notice of any such subpoenas. 1 .9. As directed by OWNER, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real-Time Kinematic) GPS Network as provided by OWNER. Information layers shall have common naming conventions (i.e. right-of-way - ROW, centerlines - CL, edge-of-pavement - EOP, etc), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT 2.1 If authorized in writing by OWNER through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in OWNER'S Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by OWNER as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. OWNER will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver 6 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If OWNER determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to OWNER of the emergency within forty-eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT'S right it otherwise may have had to seek an adjustment to its compensation or time of performance under this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: 2.2. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.3. Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, OWNER'S schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by OWNER when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT'S control and fault. 2.4. Providing renderings or models for OWNER'S use. 2.5. Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic 7 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, I i evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting OWNER in obtaining such process licensing. 2.6. Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.7. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by OWNER, other than visits to the Project site or OWNER's office. 2.8. Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2.9. Preparing to serve or serving as a CONSULTANT or witness for OWNER in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as part of the Basic Services to be provided herein). 2.10. Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice. ARTICLE THREE OWNER'S RESPONSIBILITIES 3.1. The OWNER shall designate in writing a project manager to act as OWNER'S representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define OWNER'S policies and decisions with respect to CONSULTANT'S services for the Project. However, the Project Manager is not authorized to issue any verbal or written orders or instructions to the CONSULTANT that would 8 #17-7062 Collier County Parks and Recreation Division Master PI Consultant:Tindale-Oliver&Associates, In,, have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONSULTANT hereunder; (b) The time the CONSULTANT is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: (a) Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; (b) Provide all criteria and information requested by CONSULTANT as to OWNER's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; (c) Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT'S disposal all available information in the OWNER'S possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; (d) Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and (e) Provide notice to CONSULTANT of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONSULTANT hereunder. 9 #17-7062 Collier County Parks and Recreation Division Master PI- . Consultant:Tindale-Oliver&Associates,I ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature•or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONSULTANT shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT'S services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from OWNER. CONSULTANT'S sole remedy against OWNER will be the right to seek an extension of time to its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT'S compensation 10 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, I 0 shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4. Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONSULTANT'S performance is or will shortly be back on schedule. 4.5. In no event shall any approval by OWNER authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by OWNER to CONSULTANT be deemed a waiver of any right or claim OWNER may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the OWNER for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): A firm fixed total price offering for a project; the risks are transferred from the County to the Consultant; and, as a business practice there are no hourly or material invoices presented, rather, the Consultant must perform to the satisfaction of the County's project manager before payment for the fixed price contract is authorized. 11 #17-7062 Collier County Parks and Recreation Division Master• �. Consultant:Tindale-Oliver&Associates, Time and Materials: The County agrees to pay the contractor for the amount of labor time spent by the Consultant 's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's mark up). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. 5.2 The hourly rates as set forth and identified in Schedule B, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above. ARTICLE SIX OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by OWNER, CONSULTANT shall deliver to OWNER copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement ("Project Documents"). OWNER shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to OWNER the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring OWNER to pay any additional compensation, CONSULTANT hereby grants to OWNER a nonexclusive, irrevocable license in all of the Project Documents for OWNER'S use on this Project. CONSULTANT warrants to OWNER that it has full right and authority to grant this license to 12 #17-7062 Collier County Parks and Recreation Division Master•�. Consultant:Tindale-Oliver&Associates, OWNER. Further, CONSULTANT consents to OWNER'S use of the Project Documents to complete the Project following CONSULTANT'S termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges OWNER may be making Project Documents available for review and information to various third parties and hereby consents to such use by OWNER. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder. The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. OWNER, or any duly authorized agents or representatives of OWNER, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and hold harmless OWNER, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph 8.1. 13 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. 8.2. The duty to defend under this Article 8 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the CONSULTANT, OWNER and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to CONSULTANT. CONSULTANT'S obligation to indemnify and defend under this Article 8 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the OWNER or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2. All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3. All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1 . All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Government, Collier County, Florida, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against OWNER for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 14 #17-7062 Collier County Parks and Recreation Division Master' !" Consultant:Tindale-Oliver&Associates, 9.3.3. All insurance coverages of CONSULTANT shall be primary to any insurance or self-insurance program carried by OWNER applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by OWNER applicable to this Project. 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. 9.4. CONSULTANT, its subconsultants and OWNER shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by OWNER, except such rights as they may have to the proceeds of such insurance held by any of them. 9.5. All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements: 9.5.1 . The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT'S own staff, unless otherwise authorized in writing by the OWNER. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the OWNER. No provision of this Agreement shall, however, be construed as constituting an agreement between the OWNER and any such other person or firm. Nor shall anything in this Agreement be deemed to give any 15 #17-7062 Collier County Parks and Recreation Division Master Pla Consultant:Tindale-Oliver&Associates, In "',t. such party or any third party any claim or right of action against the OWNER beyond such as may then otherwise exist without regard to this Agreement. 10.2. Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. CONSULTANT also has identified each subconsultant and subcontractor it intends to utilize on the Project in Schedule F. All personnel, subconsultants and subcontractors identified in Schedule F shall not be removed or replaced without OWNER'S prior written consent. 10.3. CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the OWNER. Each subconsultant or subcontract agreement shall preserve and protect the rights of the OWNER under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the subconsulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub-subconsultants or sub-subcontractors. 10.4. CONSULTANT acknowledges and agrees that OWNER is a third party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between OWNER and any subconsultant or subcontractor. Further, all such contracts shall 16 #17-7062 Collier County Parks and Recreation Division Master Pia Consultant:Tindale-Oliver&Associates, Ino— provide that, at Owner's discretion, they are assignable to OWNER upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS 11.1. CONSULTANT'S acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against OWNER arising out of this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANT'S services nor payment by OWNER shall be deemed to be a waiver of any of OWNER'S rights against CONSULTANT. ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT'S failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT'S failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT'S principals, officers or directors, or (d) CONSULTANT'S failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT'S failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that OWNER otherwise was not entitled to the remedy against CONSULTANT 17 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. i C provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against OWNER shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below. 12.3. OWNER shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such termination for convenience, CONSULTANT'S recovery against OWNER shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against OWNER, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. 12.4. Upon termination and as directed by Owner, the CONSULTANT shall deliver to the OWNER all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Section 6, that are in CONSULTANT'S possession or under its control. 12.5. The OWNER shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT'S sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 18 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates 12.6 In the event (i) OWNER fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) OWNER otherwise persistently fails to fulfill some material obligation owed by OWNER to CONSULTANT under this Agreement, and (ii) OWNER has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after giving OWNER a second fourteen (14) days written notice of CONSULTANT'S intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to OWNER of CONSULTANT'S intent to terminate this Agreement. If OWNER does not cure its default within fourteen (14) days after receipt of CONSULTANT'S written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the OWNER, terminate the Agreement and recover from the Owner payment for Services performed through the termination date, but in no event shall CONSULTANT be entitled to payment for Services not performed or any other damages from Owner. ARTICLE THIRTEEN CONFLICT OF INTEREST 13.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. 19 #17-7062 Collier County Parks and Recreation Division Master PI- Consultant:Tindale-Oliver&Associates, . ARTICLE FOURTEEN MODIFICATION 14.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE FIFTEEN NOTICES AND ADDRESS OF RECORD 15.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the OWNER shall be in writing and shall be delivered by hand, by fax, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following OWNER'S address of record: Board of County Commissioners, Collier County Florida Collier County Parks and Recreation 15000 Livingston Road Naples, Florida 34109 Telephone: 239-252-4035 Attention: Barry Williams, Division Director - Parks & Recreation Email: barrywilliams@colliergov.net 15.2. All notices required or made pursuant to this Agreement to be given by the OWNER to the CONSULTANT shall be made in writing and shall be delivered by hand, by fax or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT'S address of record: Tindale-Oliver & Associates, Inc. 1000 N. Ashley Drive, Suite 400 Tampa, Florida 33602 Telephone: 813-224-8862 Fax: 813-226-2106 Attn: Virginia L. Corless, Vice President Email: gcorless@tindaleoliver.com 15.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. 20 la #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. ARTICLE SIXTEEN MISCELLANEOUS 16.1. CONSULTANT, in representing OWNER, shall promote the best interests of OWNER and assume towards OWNER a duty of the highest trust, confidence, and fair dealing. 16.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 16.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of OWNER. 16.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 16.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 16.6. In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Request for Proposal (RFP), the Consultant's Proposal, and/or the County's Board approved Executive Summary, the Contract Documents shall take precedence. 16.7. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth 21 #17-7062 Collier County Parks and Recreation Division Master Plar Consultant:Tindale-Oliver&Associates, In. herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 16.8. Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 16.9. This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 16.10. The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE Schedule E KEY PERSONNEL, SUBCONSULTANTS AND SUBCONTRACTORS RFP # 17-7602 Terms and Conditions CONSULTANT'S PROPOSAL ARTICLE SEVENTEEN APPLICABLE LAW 17.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 22 #17-7062 Collier County Parks and Recreation Division Master Plan 0 Consultant:Tindale-Oliver&Associates, Inc , ARTICLE EIGHTEEN SECURING AGREEMENT/PUBLIC ENTITY CRIMES 18.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. At the time this Agreement is executed, CONSULTANT shall sign and deliver to OWNER the Truth-In-Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E. CONSULTANT'S compensation shall be adjusted to exclude any sums by which OWNER determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 18.2. By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by OWNER of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." 23 • #17-7062 Collier County Parks and Recreation Division Master PI- Consultant:Tindale-Oliver&Associates, Inc. ARTICLE NINETEEN DISPUTE RESOLUTION 19.1. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached during negotiations to OWNER for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached at mediation to OWNER'S board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 19.2. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE TWENTY IMMIGRATION LAW COMPLIANCE 20.1. By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. ******* • 24 • #17-7062 Collier County Parks and Recreation Division Master Pla Consultant:Tindale-Oliver&Associates, Inc. IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement for Master Planning Consulting Services the day and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS FOR COLLIER COUNTY, FLORIDA, Dwight E. Brock, Clerk B DIV:LCL)L\Pc Date: rZ jJ7 By: Attest as t Chairman's Penny T r, Chair signature only. A•• ed as to Form and Legality: Deputy County Attorney eof Name Tindale-Oliver & Associates, Inc. Witn ss Lucy Bengochea-Accounting Manager Steven A. Tindale-President Name and Title Name and Title Witnes Angel P. Acey-Hayden - Accountant/Contract Administrator Name and Title ciC\ 25 0#17-7062 Collier County Parks and Recreation Division Master PI- Consultant:Tindale-Oliver&Associates, Inc. SCHEDULE A SCOPE OF SERVICES Background The Collier County Parks and Recreation Division's focus is to provide the public, both residents and visitors, with unique recreation experiences. The County's parks, open space, preserves, and recreation facilities contribute to the health of the community's residents, enhance the integrity and quality of the natural environment, and attract visitors to the community, thereby contributing to local tourism and economic development. To optimize the County's existing parks and recreation resources and assets, as well as strategically plan for the future, the County is interested in preparing a Parks and Recreation Master Plan. The master planning process is designed to ensure that Collier County Parks and Recreation Division legacy of parks, open spaces, and preserves will continue into the future and that community resources will be dedicated to programs and facilities that are desired by and will be utilized by citizens. Detailed Scope of Work The Consultant is responsible for providing the following tasks: Task 1 — Project Kick-Off, Existing Conditions Inventory and Analysis Task 2 — Review of Plans and Documents Task 3 — Public Engagement Task 4 — Development of Supply/Demand & Demographics/Trend Analysis Task 5 — Needs Assessment; Development of Vision, Design Guidelines and Implementation Strategy Task 6 — Master Plan Development Public Involvement This project shall include public involvement, with participation from the Board of Collier County Commissioners, County staff, County Advisory Boards (example — Parks and Recreation c-i #17-7062 Collier County Parks and Recreation Division Master Plan; Consultant:Tindale-Oliver&Associates, Inc. Advisory Board, Tourist Development Council, Golden Gate Community Center Advisory Board, Conservation Collier Land Acquisition Committee, property owners/neighborhood associations (including Presidents Council), community stakeholders and park users. A minimum of five (5) public meetings, one in each County district should be provided by the proposer. Tasks shall include: • Assist County staff with developing and completing a public involvement process that encourages diverse participation. • Attend meetings to gather input and provide project updates. • Provide graphic and written information as required to support public outreach effort. Preparation of GIS information highly desirable. • The selected Consultant must be prepared to present project updates at Board of Collier County Commission meetings or the Parks and Recreation Advisory Board meetings at various stages of task completion (meetings may be held jointly or separate as determined by County staff and firm). Task 1 — Project Kick-Off, Existing Conditions Inventory and Analysis Project Kick-Off Meeting The Consultant will facilitate a kick-off meeting with key County staff to receive available information related to the project, identify and discuss any technical and policy issues, coordinate staff/Consultant responsibilities, and refine the project schedule. The Consultant should be prepared to: • Prepare a report that identifies and summarizes issues and opportunities. • Present information to Board of Collier County Commissioner and Advisory Boards understanding the Board of Collier County Commissioner's sentiment towards the needs, desires, opportunities and constraints of County parks, facilities, and programs. C-2 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. Inventory The Consultant, with staff assistance, will develop a comprehensive inventory of the County's existing parks and recreation facilities that will include the following: • Park type and purpose • Park location (address) • Acreage • Inventory of facilities and amenities • Assessment of physical conditions and functionality • Available programs and events • Maps illustrating the location and each type of park • Maps illustrating pedestrian, bicycle and vehicular access to all County parks Task 2 — Review of Plans and Documents This task includes a review of plans and documents that are relevant to the development of the Final Master Plan. This review includes, but is not limited to the following: • Comprehensive Plan • Level of Service, Recreation and Open Space Element • Parks Connectivity • Community Redevelopment Area Master Plan • Collier County Parks and Recreation Master Plan • Collier County Parks and Recreation Division Capital Improvement Plan — Parks and Recreation • Collier County Parks and Recreation Division Budget— Parks and Recreation • Hunden Strategic Partners Sports Tourism Study C-3 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc ; • Blue Zone Initiative Task 3 — Public Engagement The kick-off to the public and participatory phase of this planning effort will re-evaluate, and reaffirm as appropriate, the community vision for the Collier County Parks and Recreation Division parks system. Particular emphasis must be placed on utilizing a diverse array of outreach methods, expanding the overall number of participants and age range of participants, facilitating participation by under-represented populations (seniors, children, youth, young adults, families, ethnic groups, low to moderate income neighborhood, etc.). The Consultant must be prepared to demonstrate how this will be achieved. A minimum of five (5) public meetings, one in each County district should be provided by the proposer. Task 4 — Development of Supply/Demand & Demographics/Trend Analysis The Consultant must evaluate the nature in which Collier County Parks and Recreation Division existing parks, facilities and recreation programming meet, or do not meet user demands and expectations and prepare recommendations that include or address the following: • Analyze demographics and trends • Analyze parks, programs, services and related finances • Review the organizational structure for the management of parks and recreation amenities • Land to population ratio • Target service area • Identify surpluses and deficiencies • Identify trends in deferred maintenance in parks C-4 #17-7062 Collier County Parks and Recreation Division Master PIC Consultant:Tindale-Oliver&Associates, I • Identify deficits in beach access and potential solutions • Expansion of capacity thru re-turfing of existing sports/athletic fields The Consultant, through reasonable consultation and investigation, should attempt to identify any future trends that might affect the provision of programming services in the Collier County Parks and Recreation Division and make recommendations on how to address them. Task 5 — Needs Assessment; Development of Vision, Design Guidelines and Implementation Strategy Needs Assessment The Consultant must prepare, distribute and evaluate a Needs Assessment (formal survey) to identify the assets and constraints of the existing system, identify standards for future development, and assess the current and future needs and priorities of the County's parks and recreation system. The formal survey, whether developed as a mail-out document or a web-based survey, must include a structured, random sample of households within the County and individual neighborhoods. The Consultant must advise how the survey will be properly maintained, controlled and how survey duplications will be avoided. Summer months will result in low survey participation as many residents reside out of state during the summer months. The milestone schedule to be provided by the Consultant must address method(s) to achieve the greatest participation. The formal needs assessment survey will include but not be limited to questions formulated relative to the following topics: • Resident use of parks/facilities/programs • General questions about Collier County Parks and Recreation Division parks • What resident families do for recreation C-5 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, IC • Residents recommendations for improvements • The importance, benefit or influence of parks and recreation activities on residential life and sense of community • General information about resident/family completing the survey The results of this task are to be documented in the Parks and Recreation Master Plan to include but not limited to the following: • Prioritize demands and identify parks and recreation opportunities • Establish level of service guidelines • Develop policy recommendations • Provide a strategic action plan Facility Planning and Design Analysis The facility planning and design analysis to be completed by the Consultant will include the following components. Park Land Analysis — An analysis of the existing and projected park land needs will be determined based on standards identified in the Comprehensive Plan, as well as a review of the National Recreation and Park Association (NRPA) acreage guidelines. Park Facility and Design Analysis —An analysis of the existing and projected park facility needs will be determined based on a review of the NRPA facility guidelines; Recommendations are to address and establish a connected system of parks with aesthetic standards for improving a unified look for the parks system, establishing a desired identity/theme/brand. Task 6 — Master Plan Development (Final Plan) The Master Plan for the parks and recreation system of the Collier County Parks and Recreation Division should reflect the needs of the residents and visitors by setting standards for C-6 #17-7062 Collier County Parks and Recreation Division Master P 4,• Consultant:Tindale-Oliver&Associates, I appropriate service, document a comprehensive graphic record of the process, and provide a guiding document for the future. The standards, through a strategic action plan, should identify the essential facilities needed to provide and sustain the level of park and recreation services that are consistent with the Comprehensive Plan that is supported and desired by the residents and necessary to support the County's seasonal visitor population. The Final Master Plan must be formatted with a template that may be updated every three to five years, or as desired by the County. C-7 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Incram SCHEDULE B BASIS OF COMPENSATION TIME AND MATERIAL 1. MONTHLY STATUS REPORTS B.1.1 As a condition precedent to payment, CONSULTANT shall submit to OWNER as part of its monthly invoice, a progress report reflecting the Project design and construction status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any then-authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1. For the Basic Services provided for in this Agreement, OWNER agrees to make monthly payments to CONSULTANT based upon CONSULTANT'S Direct Labor Costs and Reimbursable Expenses in accordance with the terms stated below. Provided, however, in no event shall such compensation exceed the amounts set forth in the table below. TASKS PHASE NOT TO EXCEED AMOUNT: Task 1 Project Kick-off, Existing Conditions Inventory and Analysis $10,600.00 1.1 Project Kick-off Meeting (conference call) $1,260.00 1.2 Progress Meetings/Coordination $2,610.00 1.3 Inventory and Field Assessment $6,730.00 Task 2 Review of Plans and Documents $3,630.00 2.1 Review of Plans and Documents $3,630.00 Task 3 Public Involvement $12,400.00 3.1 Community Contact Lists $1,170.00 3.2 Geographic Community Workshops $11,230.00 Task 4 Development of Supply/Demand & Demographics/Trend Analysis $16,280.00 4.1 Community Profile $4,240.00 4.2 Trend Analysis $3,310.00 4.3 Organizational and Financial Assessment $3,890.00 4.4 Findings Report $2,740.00 4.5 PRAB Presentation #1 $2,100.00 Task 5 Needs Assessment $6,370.00 5.1 Needs Assessment Survey $3,960.00 5.2 Park Land and Level of Service Analysis $2,410.00 Task 6 Master Plan Development (Final Plan) $25,550.00 6.1 Master Plan Recommendations $5,720.00 6.2 Prioritized Recommendations and Order-of-Magnitude Cost Estimates $4,230.00 6.3 Draft Master Plan Document $8,880.00 6.3 Draft Final Master Plan Document and Presentations (PRAB & BOCC) 6,720.00 TOTAL FEE (Total Tasks 1-6) $74,830.00 C-1 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. B.2.2. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT'S personnel, with respect to this Project, including all indirect payroll related costs and fringe benefits, all in accordance with and not in excess of the rates set forth in the Attachment Ito this Schedule B. B.2.3. With each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by OWNER, regarding CONSULTANT'S Direct Labor Costs incurred at the time of billing, to be reviewed and approved by OWNER. B.2.4 For Additional Services provided pursuant to Article 2 of the Agreement, OWNER agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the provisions of Section 3.5.1 below. There shall be no overtime pay on Basic Services or Additional Services without OWNER'S prior written approval. B.2.5. The compensation provided for under Sections 2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6 Notwithstanding anything in this Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by OWNER, pending resolution of the dispute provided that OWNER continues to pay to CONSULTANT all amounts that OWNER does not dispute are due and payable. 3. SCHEDULE OF PAYMENTS: B.3.1. CONSULTANT shall submit, with each of the monthly status reports provided for under Section 1.1 of this Schedule B, an invoice for fees earned in the performance of Basic Services and Additional Services during the subject billing month. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees and Reimbursable Expenses earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by Owner. Additionally, the number of the purchase order granting approval for such services shall appear on all invoices. B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of"laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. • C-2 #17-7062 Collier County Parks and Recreation Division Master PL Consultant:Tindale-Oliver&Associates, Inc. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT'S letterhead and must include the Purchase Order Number and the Project name and shall not be submitted more than one time monthly. B.3.3. Notwithstanding anything herein to the contrary, in no event may CONSULTANT'S monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task limits set forth in the table in Section 2.1 by the percentage Owner has determined CONSULTANT has completed such task as of that particular monthly billing. B.3.4. Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. B.3.5 Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for Additional Services, CONSULTANT shall be limited to a maximum markup of 5% on the fees and expenses associated with such subconsultants and subcontractors. B.3.5.1 Reimbursable Expenses associated with Additional Services must comply with section 112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items: B.3.5.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.5.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by OWNER. Such expenses, if approved by OWNER, may include coach airfare, standard accommodations and meals, all in accordance with section 112.061, F.S. Further, such expenses, if approved by OWNER, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.5.1.3. Permit Fees required by the Project. B.3.5.1.4. Expense of overtime work requiring higher than regular rates approved in advance and in writing by OWNER. B.3.5.1.5. Expense of models for the County's use. B.3.5.1.6. Other items on request and approved in writing by the OWNER. • C-3 #17-7062 Collier County Parks and Recreation Division Master Pla Consultant:Tindale-Oliver&Associates, Inc. Attachment 1 SCHEDULE B CONSULTANT'S AND SUBCONSULTANT(S) HOURLY RATE SCHEDULE Title Hourly Rate Tindale Oliver Principal Planner $195.00 Senior Planner $165.00 Project Manager $135.00 Project Planner $95.00 Landscape Architect $95.00 Planner/GIS $75.00 Administrative $60.00 GAI Recreation Planner $150.00 GIS $105.00 The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added upon mutual agreement in advance and in writing by the Project Manager and the Consultant, without further Board approval. Subconsultant fees are included in the Schedule B, Section B.2.1. Invoices for subconsultant services which have been provided on a Time and Materials basis shall include a reference to the appropriate task at the time the invoice is submitted, along with the appropriate associated hourly rate. END OF SCHEDULE B. C-4 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. SCHEDULE C PROJECT MILESTONE SCHEDULE Cumulative Number of Calendar Days For Completion Tasks Description from Date of Notice to Proceed for Services under this Agreement Task 1 Kick off, Existing Conditions, Inventory 90 Days & Analysis Task 2 Review of Plans & Documents 45 Days Task 3 Public Involvement On-going Task 4 Supply/Demand & 120 Days Demographics/Trend Analysis Task 5 Needs Assessment 180 Days Task 6 Draft Master Plan 240 Days Task 7 Final master Plan 300 Days c-i 0 #17-7062 Collier County Parks and Recreation Division Master arr,c) Consultant:Tindale-Oliver&Associates, In . SCHEDULE D INSURANCE COVERAGE (1) The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the below listed minimum required coverage, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be CONSULTANT'S sole responsibility. (2) The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. (3) Coverage shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the OWNER or as specified in this Agreement, whichever is longer. (4) Certificates of insurance (3 copies) acceptable to the OWNER shall be filed with the OWNER within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverage and limits required hereunder. In addition, certified, true and exact copies of all insurance policies required shall be provided to OWNER, on a timely basis, if requested by OWNER. Such certificates shall contain a provision that coverage afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the OWNER. CONSULTANT shall also notify OWNER, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverage or limits received by CONSULTANT from its insurer, and nothing contained herein D-1 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, l. r shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. (5) All insurance coverage of the CONSULTANT shall be primary to any insurance or self insurance program carried by the OWNER applicable to this Project. (6) The acceptance by OWNER of any Certificate of Insurance does not constitute approval or agreement by the OWNER that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. (7) CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the OWNER. (8) Should at any time the CONSULTANT not maintain the insurance coverage required herein, the OWNER may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverage and charge the CONSULTANT for such coverage purchased. If CONSULTANT fails to reimburse OWNER for such costs within thirty (30) days after demand, OWNER has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between OWNER and CONSULTANT. The OWNER shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverage purchased or the insurance company or companies used. The decision of the OWNER to purchase such insurance coverage shall in no way be construed to be a waiver of any of its rights under the Agreement. D-2 #17-7062 Collier County Parks and Recreation Division Ma er n Consultant:Tindale-Oliver&Associat r c. (9) If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the OWNER, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the OWNER with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and OWNER may terminate the Agreement for cause. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY Required by this Agreement? _X Yes No (1) Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability: X $1,000,000 Each Accident $1,000,000 Disease Aggregate $1,000,000 Disease Each Employee (2) The insurance company shall waive all claims rights against the OWNER and the policy shall be so endorsed. COMMERCIAL GENERAL LIABILITY Required by this Agreement? _X Yes No D-3 #17-7062 Collier County Parks and Recreation Division Master' Consultant:Tindale-Oliver&Associates, • (1) Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the OWNER of the work under this Agreement. Limits of Liability shall not be less than the following: X Single Limit per Occurrence $1,000,000 Products/Completed Operations Aggregate $2,000,000 Aggregate $2,000,000 (2) The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. (3) The OWNER, Collier County Board of County Commissioners, Board of County Commissioners in Collier County, or Collier County Government, shall be named as an Additional Insured and the policy shall be endorsed that such coverage shall be primary to any similar coverage carried by the OWNER. AUTOMOBILE LIABILITY INSURANCE Required by this Agreement? _X_Yes No D-4 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. (1) Automobile Liability Insurance shall be maintained by the CONSULTANT for the ownership, maintenance or use of any owned, non-owned or hired vehicle with limits of not less than: X Bodily Injury & Property Damage - $1,000,000 UMBRELLA LIABILITY (1) Umbrella Liability may be maintained as part of the liability insurance of the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverage required herein and shall include all coverage on a "following form" basis. (2) The policy shall contain wording to the effect that, in the event of the exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. PROFESSIONAL LIABILITY INSURANCE Required by this Agreement? X Yes No (1) Professional Liability Insurance shall be maintained by the CONSULTANT to insure its legal liability for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recover against OWNER as to any claims under this insurance. Such insurance shall have limits of not less than: X $1,000,000 each claim and in the aggregate (2) Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT. Deductible amounts are subject to the approval of the OWNER. D-5 #17-7062 Collier County Parks and Recreation Division Master Plary� Consultant:Tindale-Oliver&Associates, I ASO (3) The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the OWNER. (4) The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or OWNER, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to OWNER of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify OWNER by certified mail, within twenty- four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverage or limits received by CONSULTANT from its insurer. In the event of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by OWNER. VALUABLE PAPERS INSURANCE (1) In the sole discretion of the County, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. PROJECT PROFESSIONAL LIABILITY (1) If OWNER notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with OWNER and OWNER'S insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT'S professional liability policy. If no credit is available from CONSULTANT'S current professional policy D-6 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. t© underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to OWNER. Should no credit accrue to OWNER, OWNER and CONSULTANT, agree to negotiate in good faith a credit on behalf of OWNER for the provision of project-specific professional liability insurance policy in consideration for a reduction in CONSULTANT'S self-insured retention and the risk of uninsured or underinsured consultants. (2) CONSULTANT agrees to provide the following information when requested by OWNER or OWNER'S Project Manager: a. The date the professional liability insurance renews. b. Current policy limits. c. Current deductibles/self-insured retention. d. Current underwriter. e. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. f. Cost of professional insurance as a percent of revenue. g. Affirmation that the design firm will complete a timely project errors and omissions application. (3) If OWNER elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and OWNER will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds. END OF SCHEDULE D D-7 #17-7062 Collier County Parks and Recreation Division Master In Consultant:Tindale-Oliver&Associates, I c. SCHEDULE E KEY PERSONNEL, SUBCONSULTANTS AND SUBCONTRACTORS Name Personnel Category % of time Tindale Oliver Design Ginger Corless Principal Planner 12% Evan Johnson Project Manager 6% Elizabeth Schuck Sr. Planner 4% Jennifer Bartlett Project Planner 12% Bonnie Bernardo Landscape Architect 3% Bryan Weinstein Project Planner 5% Alex Law Planner 14% Patrick Dougherty Planner/GIS 14% Nilgun Kamp Principal Planner 3% GAI Kristen Caborn Recreational Planner 12% Patrick Panza GIS 8% E-1 #17-7062 Collier County Parks and Recreation Division Master Plan Consultant:Tindale-Oliver&Associates, Inc. Collier Comity Administrative Services Department Procurement Services Division Date: 24 February 2017 Notice of Recommended Award Solicitation : 17-7062 Title: Coifies art r9 f es 2e-r....,/e-0 74cr tios'ry t /9/7et54e- f Due Date and Time: j ..a e4,,,,,L,r- 2 2.r 2,„o 1t., Respondents: Company Name City County State Bid Amount Responsive/Responsible Tindale Oliver Design Tampa Hillsborough FL - Yes Group AECOM Ft. Myers Lee FL - _ Yes Sand County Studios Smyrna Cobb GA - Yes Barth Associates Gainesville Alachua FL - Yes Stantec Naples Collier FL - Yes Utilized Local Vendor Preference: Yes 111111 f No Recommended Vendor(s) For Award: Tindale Oliver Design Group Required Signatures Project Manager: Barry Williams Signature:, � `!71 '% :,1/ /7 Procurement Strategist: Matt Catoe Signature: ' , �� ;,�%` 45",,4,4-„u /44.1-6 peg. ,4,977 re4To c--r{) rre• -nt�. vices ' ector: P Edward F. Coyman Jr. m [ f o 0 o c o e o 0 o c o '§ \ o m° f / / // - G / / r & CO 4 6 o g iz) / -o \ & g -3 a) ƒ ® f CO @ x fe ; A mar # § < / / / a) E 5 : > E / E -o § c — # V) U) C13 % 2 § E $ U 2 ) \ � ƒ 77 E / o / n — cr ~ \ i a 0 � _ e / / _ / ai 2 = _ • § $ E _ # CO g in co c a - a 2 a. ca \ \ / = r-- Cr. \ / E § \ / a) ^ c E @ 6 a) $ \ / m — # § a / oE A % li o g % / E \ : f E / w N ac / ƒ \ n m % \ _ \ \ � co / � � u @ % / ` J / f •o / .2 § % \ 2 L 2 / 2 ■ = E 2 I 6 • a - L = \ '� § 2 / \ \ E a. § E a c '_ 2 = 2 g m = 5 c = / .� e 2 w:\ . ± g ° U) ° ° n = B \ ) \ a \ \ ea \ 7 2 §/ / $ / a) o 0 / 8 d'/ ¥ . 46 / \ / E ,1,,-,....,:t �\ - / / \ 0 $ > § / a ±_ ../: ° \ O. \ k / / \ k / 0 § / m@ $ f R I « 3 G R c ACORD Client#: 1048400 TINDAOLI1 DATE(MM/DD/YYYY) TM CERTIFICATE OF LIABILITY INSURANCE 3/29/2017 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed.If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: USI Insurance Services,LLC, r-"""` 813 321-7500 FAX(AJC, (A/C,No,Ext): No): 1715 N.Westshore Blvd.Suite 700 E-MAIL ADDRESS: Tampa, FL 33607 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:Travelers Property Cas.Co. 25674 INSURED INSURER B:Commerce&Industry Insurance 19410 Tindale-Oliver&Associates, Inc. 1000 N Ashley Dr.,Suite 400 INSURER C:Travelers Casualty and Surety 31194 Tampa,FL 33602 INSURER D:XL Specialty Insurance Company 37885 INSURER E:Travelers Indemnity Company 25682 INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP WLIMITS LTR INSR VD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) A X COMMERCIAL GENERAL LIABILITY X X 6807H273337 02/24/2017 02/24/2018 EACH OCCURRENCE $1,000,000 DAMAGE TO RENTED CLAIMS-MADE X OCCUR PREMISES(Ea occurrence) $1,000,000 MED EXP(Any one person) $10,000 PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 sv,1IF'ttU- JECT I POLICY I . LOC PRODUCTS-COMP/OPAGG $2,000,000 OTHER: $ E AUTOMOBILE LIABILITY X X BA8130L506 02/24/2017 02/24/2018 COMBINED SINGLE LIMIT (Ea accident) $1,000,000 ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS XX NON-OWNED PeOrP cider RERTY DAMAGE HIRED AUTOS AUTOS ( ) $ B X UMBRELLA LIAB X OCCUR X X 6E096059640 02/24/2017 02/24/2018 EACH OCCURRENCE $9,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $9,000,000 DED X RETENTION$0 $ C WORKERS COMPENSATION X UB7082Y317 09/01/2016 09/01/2017 X PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE Y/N E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 D Professional DPR9804135 04/20/2016 04/20/2017 $2,000,000 per claim Liability $2,000,000 annl aggr. DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Professional Liability coverage is written on a claims-made basis. RE: For All Projects for Collier County Board of County Commissioners Collier County Board of County Commissioners are included as an additional insured under the captioned General Liability and Automobile Liability policies on a primary and non contributory basis if and to thee extent by written contract. Waiver of subrogation applies to all policies listed above in favor of the additional insureds as required by written contract. CERTIFICATE HOLDER CANCELLATION Collier County Board f CSHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE tyoaroount y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Commissioners ACCORDANCE WITH THE POLICY PROVISIONS. 3327 Tamiami Trail East Naples, FL 34112 AUTHORIZED REPRESENTATIVE ©1988-2014 ACORD CORPORATION.All rights reserved. ACORD 25(2014101) 1 of 1 The ACORD name and logo are registered marks of ACORD #S20176298/M19901093 MRLEW