Loading...
Backup Documents 11/18/2014 Item #16A23 (Quality Enterprises) 3 ORIGINAL DOCUMENTS CHECKLIST&ROUTING SLIP 1 6 A 2 TO ACCOMPANY ALL ORIGINAL DOCUMENTS SENT TO THE BOARD OF COUNTY COMMISSIONERS OFFICE FOR SIGNATURE'€(��"� 1 20 Routed by Purchasing Department to the Office Initials Date FolloWing Addressee(s) (In routing order) 1. Risk Management Risk 2. County Attorney Office County Attorney Office 3. BCC Office Board of County Commissioners "\?- V4A 4. Minutes and Records Clerk of Court's Office (1(2t(14 3'32prr 5. Return to Purchasing Department Purchasing Contact: Diana DeLeon PRIMARY CONTACT INFORMATION Name of Primary Diana De Leon for Evelyn Colon Phone Number 252-8375 Purchasing Staff November 19,2014 Contact and Date Agenda Date Item was November 18,2014✓ Agenda Item Number 16.A.231/- Approved 6.A.23✓Approved by the BCC Type of Document Contract Number of Original 2 Attached Documents Attached PO number or account N/A Solicitation/Contract 14-6212 Quality number if document is NumberNendor Name Enterprises USA to be recorded INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A"in the Not Applicable column,whichever is Yes N/A(Not appropriate. (Initial) ` Applicable) 1. Does the document require the chairman's original signature? DD 2. Does the document need to be sent to another agency for additional signatures? If yes, N/A provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be �p(� signed by the Chairman,with the exception of most letters,must be reviewed and signed �1`IW�"'r by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the N/A document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's DD signature and initials are required. 7. In most cases(some contracts are an exception),an electronic copy of the document and DD this routing slip should be provided to the County Attorney's Office before the item is input into SIRE. 8. The document was approved by the BCC on the date above and all changes made DD during the meeting have been incorporated in the attached document. The County Attorney's Office has reviewed the changes,if applicable. 9. Initials of attorney verifying that the attached document is the version approved by the e BCC,all changes directed by the BCC have been made,and the document is ready for th; Chairman's signature. 1 6 A 2 3 MEMORANDUM Date: November 24, 2014 To: Diana De Leon, Contracts Technician Purchasing & General Services Department From: Teresa Cannon, Deputy Clerk Minutes & Records Department Re: Contract #14-6212 "Annual Contract for Bridge Repair and Maintenance" Contractor: Quality Enterprises USA Attached is an original copy of the contract referenced above, (Item #16A23) approved by the Board of County Commissioners on Tuesday, November 18, 2014. The second original contract will be held in the Minutes and Records Department for the Board's Official Record. If you have any questions, please contact me at 252-8411. Thank you. Attachment 1 642 7 AGREEMENT 14-6212 for Annual Contract for Bridge Repairs and Maintenance THIS AGREEMENT is made and entered into this 134-4 day of Nnv h 2014, by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "County" or "Owner") and Quality Enterprises USA, Inc., authorized to do business in the State of Florida, whose business address is 3894 Mannix Drive, Suite 216, Naples, Florida 34114 (hereinafter referred to as the "Contractor"). WITNESSETH: 1. COMMENCEMENT. The contract shall be for a one (1) year period, commencing on Date of Board Award and terminating one (1) year from that date, or until such time as all outstanding services ("Work") requested prior to the expiration of the Agreement period have been completed or terminated. This contract shall have three (3) additional, one (1) year renewals, renewable annually. The County Manager, or his designee, may, at his discretion, extend the Agreement under all of the terms and conditions contained in this Agreement for up to one hundred eighty (180) days. The County Manager, or his designee, shall give the Contractor written notice of the County's intention to extend the Agreement term not less than ten (10) days prior to the end of the Agreement term then in effect. 2. STATEMENT OF WORK. The Board of County Commissioners deemed two (2) firms to be qualified and awarded a Contract to each firm. Each awardee will enter into an Agreement to provide complete services for bridge repairs and maintenance on an as-needed basis as may be required by the Owner in accordance with the terms and conditions of RFP #14-6212, including Exhibit 1-A, Scope of Work, and the Contractor's proposal, which is incorporated by reference and made an integral part of this Agreement. The execution of this Agreement shall not be a commitment to the Contractor that any Work will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the procedure to obtain Work outlined in the next paragraphs and all Work undertaken by Contractor for Owner pursuant to this Agreement during the term and any extension of the term of this Agreement. Although the primary user of this Contract is the Growth Management Division, any County Division may use this contract provided sufficient funds are included in its budget. The process for obtaining services under this Contract is as follows: For Projects estimated to be less than $50,000: The Owner may select one of the awarded Contractor(s); quote out the Work among all awarded Contractor(s); or competitively solicit for new quotes. Page -1- c� 1 6 A 2 3 For Projects estimated to be greater than $50,000 and less Two Hundred Thousand Dollars ($200,000): The Owner shall obtain written quotations from all the awarded Contractors; or competitively solicit for new quotes. The Contractor(s) shall respond with a written quotation within three (3) working days. The Owner will then issue an internal departmental Work Order and subsequently issue a Notice to Proceed provided there has been a Purchase Order (or blanket purchase order) established for the Work. In each Request for Quotations, the Owner reserves the right to specify: the period of completion; collection of liquidated damages in the event of late completion; time and materials or lump sum; and may negotiate favorable project terms and conditions. This Agreement contains the entire understanding between the parties and any modifications to this Agreement shall be mutually agreed upon in writing by the Contractor and the County project manager or his designee, in compliance with the County Purchasing Ordinance and Procedures in effect at the time such services are authorized. 3. THE CONTRACT SUM. The Owner shall pay the Contractor for the performance of the Work pursuant to the quoted price offered by the Contractor in his response to a specific Request for Quotation. Any County agency may utilize the services offered under this contract, provided sufficient funds are included in its budget(s). 4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following Contractor's address of record: Quality Enterprises USA, Inc. 3894 Mannix Drive, Suite 216 Naples, Florida 34114 Phone: 239-435-7200; Fax: 239-435-7202 Attn: Louis J. Gaudio, Vice President Email: Igaudio(a)geusa.com All notices required or made pursuant to this Agreement to be given by the Contractor to the County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following County's address of record: Collier County Government Complex Procurement Services Department 3327 East Tamiami Trail Naples, Florida 34112 Attention: Joanne Markiewicz Director, Procurement Services Phone: 239-252-8407 Fax: 239-252-6480 Page -2- cy�� 1 6 A 2 3 The Contractor and the County may change the above mailing address at any time upon giving the other party written notification. All notices under this Service Agreement must be in writing. 5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a partnership between the County and the Contractor or to constitute the Contractor as an agent of the County. 6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all such permits issued by the County shall be processed internally by the County. Contractor is not responsible for paying for permits issued by Collier County, but is responsible for acquiring all permits. Owner may require the Contractor to deliver internal budget transfer documents to applicable Collier county agencies when the Contractor is acquiring permits. All permits, fees and licenses necessary for the prosecution of the Work which are not issued by Collier County shall be acquired and paid for by the Contractor. Owner will not be obl!gated to pay for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. 7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation, or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the event of such violation by the Contractor or if the County or its authorized representative shall deem any conduct on the part of the Contractor to be objectionable or improper, the County shall have the right to suspend the Contract of the Contractor. Should the Contractor fail to correct any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24) hours after receiving notice of such violation, conduct, or practice, such suspension to continue until the violation is cured. The Contractor further agrees not to commence operation during the suspension period until the violation has been corrected to the satisfaction of the County. 8. TERMINATION. Should the Contractor be found to have failed to perform his services in a manner satisfactory to the County and requirements of this Agreement, the County may terminate said Agreement for cause; further the County may terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be sole judge of non-performance. 9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race, sex, color, creed or national origin. 10. INSURANCE. The Contractor shall provide insurance as follows: A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability. This shall include Premises and Operations; Independent contractors; Products and Completed Operations and Contractual Liability. B. Business Auto Liability: Coverage shall have minimum limits of $1,000,000 Per Occurrence, Combined Single Limit for Bodily Injury Liability and Property Damage Liability. Page -3- 16A23 This shall include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non- Ownership. C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in compliance with the applicable state and federal laws. The coverage must include Employers' Liability with a minimum limit of$500,000 for each accident. D. Pollution: The coverage must include a minimum limit of$1,000,000 per occurrence. Special Requirements: Collier County Board of County Commissioners shall be listed as the Certificate Holder and included as an Additional Insured on the Comprehensive General Liability. Current, valid insurance policies meeting the requirement herein identified shall be maintained by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification to the County in the event of cancellation or modification of any stipulated insurance coverage. Contractor shall insure that all subcontractors comply with the same insurance requirements that he is required to meet. The same Contractor shall provide County with certificates of insurance meeting the required insurance provisions. 11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall indemnify and hold harmless Collier County, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. This section does not pertain to any incident arising from the sole negligence of Collier County. 11.1 The duty to defend under this Article 11 is independent and separate from the duty to indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor, County and any indemnified party. The duty to defend arises immediately upon presentation of a claim by any party and written notice of such claim being provided to Contractor. Contractor's obligation to indemnify and defend under this Article 10 will survive the expiration or earlier termination of this Agreement until it is determined by final judgment that an action against the County or an indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable statute of limitations. 12. PAYMENTS WITHHELD. Owner may decline to approve any invoice, or portions thereof, because of defective or incomplete work, subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole or any part of any approval for payment previously issued and Owner may withhold any payments otherwise due Contractor under this Agreement or any other agreement between Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable evidence indicating probable fling of such Page -4- CAo 1 6 A 2 3 claims; (c) failure of Contractor to make payment properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of the Work by the Contractor; or (g) any other material breach of the Contract Documents. If any conditions described above are not remedied or removed, Owner may, after three (3) days written notice, rectify the same at Contractor's expense. Owner also may offset against any sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to Owner, whether relating to or arising out of this Agreement or any other agreement between Contractor and Owner. 13. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from specifications shall be approved in writing by Owner in advance. 14. CONTRACT TIME AND TIME EXTENSIONS. A. Time is of the essence in the performance of any Work under this Agreement and Contractor shall diligently pursue the completion of the Work and coordinate the Work being done on the Project by its subcontractors and materialmen, as well as coordinating its Work with all work of others at the Project Site, so that its Work or the work of others shall not be delayed or impaired by any act or omission by Contractor. Contractor shall be solely responsible for all construction means, methods, techniques, sequences, and procedures as well as coordination of all portions of the Work under the Contract Documents, and the coordination of Owner's supplies and contractors. B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or neglect, including but not restricted to acts of Nature or of the public enemy, acts of Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor shall notify the Owner in writing within forty-eight (48) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Contractor may have had to request a time extension. C. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which Owner may be responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to any right to damages or additional compensation from Owner. Contractor expressly acknowledges and agrees that it shall receive no damages for delay. Contractor's sole remedy, if any, against Owner will be the right to seek an extension to the Contract Time; provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as to claims based on late completion. 15. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the Work to increase or decrease the Work. Promptly after being notified of a change, Contractor shall submit an itemized estimate of any cost or time increases or savings it foresees as a result of the change. Except in an emergency endangering life or property, or as expressly set forth herein, no addition or changes to the Work shall be made except upon modification of the Purchase Order or written order by Owner, and Owner shall not be liable to the Page -5- c1� 16423 Contractor for any increased compensation without such modification. No officer, employee or agent of Owner is authorized to direct any extra or changed work orally. Any modifications to this Contract shall be in compliance with the County Purchasing Ordinance and Procedures in effect at the time such modifications are authorized. 16. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this contract in accordance with the Purchasing Ordinance and Purchasing Procedures. 17. COMPLIANCE WITH LAWS. Contractor agrees to comply, at its own expense, with all federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements applicable to the Project, including but not limited to those dealing with taxation, workers' compensation, equal employment and safety (including, but not limited to, the Trench Safety Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119 (including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(d) and (3)), ordinances). If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify Owner in writing. 18. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish and waste materials arising out of the Work. At the completion of the Work, Contractor shall remove all debris, rubbish and waste materials from and about the Project site, as well as all tools, appliances, construction equipment and machinery and surplus materials, and shall leave the Project site clean and ready for occupancy by Owner. 19. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or any part thereof, it shall require that its assignee be bound to it and to assume toward Contractor all of the obligations and responsibilities that Contractor has assumed toward Owner. 20. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's Proposal, and/or the County's Board approved Executive Summary, the Contract Documents shall take precedence. 21. WARRANTY. Contractor expressly warrants that the goods, materials and/or equipment covered by this Agreement will conform to the requirements as specified, and will be of satisfactory material and quality production, free from defects, and sufficient for the purpose intended. Goods shall be delivered free from any security interest or other lien, encumbrance or claim of any third party. Any services provided under this Agreement shall be provided in accordance with generally accepted professional standards for the particular service. These warranties shall survive inspection, acceptance, passage of title and payment by the County. Contractor further warrants to Owner that all materials and equipment furnished under the Contract Documents shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturers, fabricators, suppliers or processors except as otherwise provided for in the Contract Documents. If, within one (1) year after final completion, any Work is found to be defective or not in conformance with the Contract Documents, Contractor shall correct it promptly after receipt of Page -6- (rA) 1 6 A 2 3 written notice from Owner. Contractor shall also be responsible for and pay for replacement or repair of adjacent materials or Work which may be damaged as a result of such replacement or repair. These warranties are in addition to those implied warranties to which Owner is entitled as a matter of law. 22. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The Contractor shall employ people to work on County projects who are neat, clean, well-groomed and courteous. Subject to the American with Disabilities Act, Contractor shall supply competent employees who are physically capable of performing their employment duties. The County may require the Contractor to remove an employee it deems careless, incompetent, insubordinate or otherwise objectionable and whose continued employment on Collier County projects is not in the best interest of the County. 23. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules or regulations of any public authority having jurisdiction over the Project requires any portion of the Work to be specifically inspected, tested or approved, Contractor shall assume full responsibility therefore, pay all costs in connection therewith and furnish to the Owner the required certificates of inspection, testing or approval. All inspections, tests or approvals shall be performed in a manner and by organizations acceptable to the Owner. 24. PROTECTION OF WORK. A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such loss or damage until final payment has been made. If Contractor or anyone for whom Contractor is legally liable is responsible for any loss or damage to the Work, or other work or materials of Owner or Owner's separate contractors, Contractor shall be charged with the same, and any monies necessary to replace such loss or damage shall be deducted from any amounts due Contractor. B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. C. Contractor shall not disturb any benchmark established by the Owner with respect to the Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by Owner associated therewith. 25. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons or the Work or property at the Project site or adjacent thereto, Contractor, without special instruction or authorization from Owner is obligated to act to prevent threatened damage, injury or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the occurrence of the emergency, if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby. If the Owner determines that a change in the Contract Documents is required because of the action taken in response to an emergency, a written Order shall be issued to document the consequences of the changes or variations. Page -7- c� 1 6 A 2 3 If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor shall be deemed to have waived any right it otherwise may have had to seek an adjustment to the Contract Amount or an extension to the Contract Time. 26. COMPLETION. Owner reserves the right to inspect the Work and make an independent determination as to the acceptability of the Work. Unless and until the Owner is completely satisfied, the final payment shall not become due and payable. 27. CONTRACT ADMINISTRATION. This Agreement shall be administered on behalf of the County by the Growth Management Division. 28. COMPONENT PARTS OF THIS CONTRACT. This Contract consists of the attached or referenced component parts, all of which are as fully a part of the Agreement as if herein set out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP #14-6212, Bridge Repairs and Maintenance, including Exhibit 1-A, Scope of Work any addenda, subsequent Purchase Orders, Quotations and Work Orders, made or issued pursuant to this Agreement. 29. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311. Violation of this provision may result in one or more of the following consequences: a. Prohibition by the individual, firm, and/or any employee of the firm from contact with County staff for a specified period of time; b. Prohibition by the individual and/or firm from doing business with the County for a specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual and/or firm for cause. 30. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the parties herein that this Agreement is subject to appropriation by the Board of County Commissioners. 31. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated with the Work or portions thereof, which are applicable during the performance of the Work. No markup shall be applied to sales tax. 32. IMMIGRATION LAW COMPLIANCE. By executing and entering into this agreement, the Contractor is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. 33. VENUE. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. Page -8- c�<? 1 6 A 2 3 34. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages and agrees to the successful proposer extending the pricing, terms and conditions of this solicitation or resultant contract to other governmental entities at the discretion of the successful proposer. 35. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall remain in effect. 36. SECURITY. If required, Contractor shall be responsible for the costs of providing background checks by the Collier County Facilities Management Department for all employees that shall provide services to the County under this Agreement. This may include, but not be limited to, checking federal, state and local law enforcement records, including a state and FBI fingerprint check, credit reports, education, residence and employment verifications and other related records. Contractor shall be required to maintain records on each employee and make them available to the County for at least four (4) years. 37. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of Contractor with full decision-making authority and by County's staff person who would make the presentation of any settlement reached during negotiations to County for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of Contractor with full decision-making authority and by County's staff person who would make the presentation of any settlement reached at mediation to County's board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 38. SAFETY. All contractors and subcontractors performing service for Collier County are required and shall comply with all Occupational Safety and Health Administration (OSHA), State and County Safety and Occupational Health Standards and any other applicable rules and regulations. Also all Contractors and subcontractors shall be responsible for the safety of their employees and any unsafe acts or conditions that may cause injury or damage to any persons or property within and around the work site. Collier County Government has authorized the Occupational Safety and Health Administration (OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of inspection of any Contractor's work operations. This provision is non-negotiable by any department and/or Contractor. All applicable OSHA inspection criteria apply as well as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow OSHA onto a project that is being performed on Collier County Property. Collier County, as the owner of the property where the project is taking place shall be the only entity allowed to refuse access to the project. However, this decision shall only be made by Collier County's Risk Management Department Safety Manager and/or Safety Engineer. Page -9- r'\" 1 6 A 2 3 IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an authorized person or agent, hereunder set their hands and seals on the date and year first above written. BOARD OF COUNTY COMMISSIONERS ATTEST: COLLIER COUNT , FLORIDA Dwig E. Brock clerk of Courts B B . J .� t B • �'� ,►:,�.� Tom Henni g, Chairman Dated: C; Attest as -.)man's sianaturo only. Quality Enterprises USA, Inc. Contractor jaiztef di 14 14 - By: First t ness Signature Susan J. Schultz Louis J. Gaudio Type/Print Witness Name Typed Signature 4.0 l.- ;" 1 Vice President Second Witness Title Marcie Cohen Type/Print Witness Name Approved as to Form and Legality: Assistant County Attorney item# l 1oti-a'3 Agenda { 1 Date Rete ` I 9 Recd ' Deputy Clerk Page -10- t I-? A-2:. . 1 1 AR o DATE(MMIDDIYYYY) CERTIFICATE OF LIABILITY INSURANCE 7/14/2014 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Rutherroord Rutherfoord (A/cC.No.Ext):757-456-0577 FAX No):757-456-5296 Central Park Avenue E-MAILS Suite 1340 Dss:Certificates rutherfoord.com ii Virginia Beach VA 23462 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:Chats Specialty Insurance Company 26883 INSURED INSURER B:First Liberty Insurance Corporation 33588 Quality Enterprises USA Inc& INSURER c:LM Insurance Corporation 33600 Quality Environment Co. INSURER 0:Liberty Mutual Fire Ins Co 23035 894 Drive Suite 216 INSURER E:American Guarantee and Liability In 26247 216 Y Naples FL 34114-5406 INSURER F: COVERAGES CERTIFICATE NUMBER:842872832 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSR WVD POLICY NUMBER (MM/DDIYYYY) (MM/DDIYYYY) LIMITS C GENERAL LIABILITY TB7Z91449711034 7/1/2014 7/1/2015 EACH OCCURRENCE $1,000,000 X DAMAGE TO RENTED COMMERCIAL GENERAL LIABILITY PREMISES(Ea occurrence) $300,000 CLAIMS-MADE X OCCUR MED EXP(My one person) $5,000 PERSONAL&ADV INJURY $1,000,000 GENERAL AGGREGATE $2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $2,000,000 —7 POLICY PRO- -7 LOC $ D AUTOMOBILE LIABILITY ASJZ91449711014 7/1/2014 7/1/2015 COMBINED SINGLE-LIMIT (Ea accident) $1,000,000 X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS NON-OWNED PROPERTY DAMAGE X HIRED AUTOS X AUTOS (Per accident) $ _ X Comp $1000 X Coll$1,000 $ E UMBRELLA LIAB X OCCUR AUC017426600 7/1/2014 7/1/2015 EACH OCCURRENCE $5,000,000 X EXCESS LIAB CLAIMS-MADE AGGREGATE _ $5,000,000 DED X RETENTION$0 $ B WORKERS COMPENSATION WC6Z91449711024 7/1/2014 7/1/2015 X WC STATU- OTH- AND EMPLOYERS'LIABILITY Y/N TORY LIMITS ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? N/A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under .,I DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 A Pollution Liability CPO025895025 7/1/2014 7/1/2015 $1,000,000 each claim $1,000,000 Aggre IIS DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101,Additional Remarks Schedule,if more space is required) RE: For Any and all County projects Collier County Commissioners are included as additional Insureds under the General Liability policy as respects to work performed by the insured,as required by written contract. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Board of County Commissioners of Collier County, Florida ACCORDANCE WITH THE POLICY PROVISIONS. 3327 Tamiami Trail East Naples FL 34112 AUTHORIZED REPRESENTATIVE OIL M. C2,0.9k ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25(2010/05) The ACORD name and logo are registered marks of ACORD