The URL can be used to link to this page

Backup Documents 06/14/2016 Item #16A17 ORIGINAL DOCUMENTS CHECKLIST & ROUTING r,P 1 6 A 1T ALL ORIGINAL DOCUMENTS SENI,71 THE BOARD OFCODACCPUNTY COMMISSIONERS OFFICE FOR SIGN'1`L1O " ® JUN 1 6 2018 COUNTY ATTORNEY P ROUTI'! l= ;, �; Risk Managcrrle„l Routed by Procurement Services to the Office Initials Date Following Addressee(s) (In routing order) 1. Risk Management Risk L L E J (p CD 2. County Attorney Office County Attorney Office b \„\o,.41-k7s) -01 -1(0 3. BCC Office Board of County Commissioners \A\c/S �4� k kto 4. Minutes and Records Clerk of Court's Office j* 2/I40 3. ' 5. Return to Procurement Services Procurement Services Division Contact: Camille S-M PRIMARY CONTACT INFORMATION Name of Primary Viviana Giarimoustas for Evelyn Colon, Phone Number 252-8998 Procurement Staff 6/16/2016 Contact and Date Agenda Date Item was 06/14/2016 _ / Agenda Item Number. Ail Approved by the BCC v Type of Document Contract ✓ Number of Original 2 '✓ Attached Documents Attached PO number or account N/A / Solicitation/Contract 15-6418/AECOM,v- number if document is ✓ Number/Company Technical Services to be recorded Name INSTRUCTIONS & CHECKLIST Initial the Yes column or mark"N/A”in the Not Applicable column,whichever is Yes N/A(Not appropriate. (Initial) Applicable) 1. Does the document require the chairman's original signature? J. ,,� 2. Does the document need to be sent to another agency for additional signature\? If yes, N/A provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet. 3. Original document has been signed/initialed for legal sufficiency. (All documents to be signed by the Chairman,with the exception of most letters,must be reviewed and signed P by the Office of the County Attorney. 4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A Office and all other parties except the BCC Chairman and the Clerk to the Board 5. The Chairman's signature line date has been entered as the date of BCC approval of the N/A document or the final negotiated contract date whichever is applicable. 6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's VSG signature and initials are required. 7. In most cases(some contracts are an exception),an electronic copy of the document and VSG this routing slip should be provided to the County Attorney's Office before the item is input into SIRE. 8. The document was approved by the BCC on the date above and all changes made VSG during the meeting have been incorporated in the attached document. The County svo Attorney's Office has reviewed the changes,if applicable. 9. Initials of attorney verifying that the attached document is the version approved by the 1 SG » BCC,all changes directed by the BCC have been made,and the document is ready for the r \ "Ruff • Chairman's signature. 1 6 A 17 MEMORANDUM Date: June 22, 2016 To: Evelyn Colon, Procurement Specialist Purchasing Department Cc: Viviana Giarimoustas, Purchasing Department From: Teresa Cannon, Deputy Clerk Minutes & Records Department Re: Contract #15-6418 AECOM Technical Services Attached is a copy of each work order referenced above, (#16A17) approved by the Board of County Commissioners on Tuesday, June 14, 2016. The original will be held on file in the Minutes and Record's Department for the Board's Official Record. If you have any questions, please feel free to contact me at 252-7240. Thank you. 16A 17 Agreement#15-6418 "Vanderbilt Drive Bridge Replacement" PROFESSIONAL SERVICES AGREEMENT THIS AGREEMENT is made and entered into this qday , 201A.0 by and between the Board of County Commissioners for Collier County, Florida, a political subdivision of the State of Florida (hereinafter referred to as the "COUNTY" or "OWNER") and AECOM Technical Services, Inc., authorized to do business in the State of Florida, whose business address is 4415 Metro Parkway, Suite 404, Fort Myers, Florida 33916 (hereinafter referred to as the "CONSULTANT" and/or "CONTRACTOR"). WITNESSETH: WHEREAS, the OWNER desires to obtain the professional Construction, Engineering and Inspection Services (CEI) of the CONSULTANT concerning Vanderbilt Drive Bridge Replacements (hereinafter referred to as the "Project"), said services being more fully described in Schedule A, "Scope of Services", which is attached hereto and incorporated herein; WHEREAS, the CONSULTANT has submitted a proposal for provision of those services; and WHEREAS, the CONSULTANT represents that it has expertise in the type of professional services that will be required for the Project. NOW, THEREFORE, in consideration of the mutual covenants and provisions contained herein, the parties hereto agree as follows: t Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 ARTICLE ONE CONSULTANT'S RESPONSIBILITY 1.1. CONSULTANT shall provide to OWNER professional CEI services in all phases of the Project to which this Agreement applies. 1.2. The Basic Services to be performed by CONSULTANT hereunder are set forth in the Scope of Services described in detail in Schedule A. The total compensation to be paid CONSULTANT by the OWNER for all Basic Services is set forth in Article Five and Schedule B, "Basis of Compensation", which is attached hereto and incorporated herein. 1.3. The CONSULTANT agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida and in Collier County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONSULTANT pursuant to this Agreement. 1.4. The CONSULTANT agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services to OWNER. 1.5. CONSULTANT designates Crystal Gorman, PE, Senior Project Manager a qualified licensed professional to serve as the CONSULTANT'S project coordinator (hereinafter referred to as the "Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the CONSULTANT with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. Further, the Project Coordinator has full authority to bind and obligate the CONSULTANT on all matters arising out of or relating to this Agreement. The CONSULTANT agrees that the Project 2 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 Coordinator shall devote whatever time is required to satisfactorily manage the services to be provided and performed by the CONSULTANT hereunder. The Project Coordinator shall not be removed by CONSULTANT from the Project without OWNER'S prior written approval, and if so removed must be immediately replaced with a person acceptable to OWNER. 1.6. CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from Owner to promptly remove and replace the Project Coordinator, or any other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to provide and perform services or work pursuant to the requirements of this Agreement, said request may be made with or without cause. Any personnel so removed must be immediately replaced with a person acceptable to OWNER. 1.7. The CONSULTANT represents to the OWNER that it has expertise in the type of professional services that will be performed pursuant to this Agreement and has extensive experience with projects similar to the Project required hereunder. The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this Agreement shall be subject to the OWNER'S review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and requirements of any governmental agencies, and the Florida Building Code where applicable, which regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and the Florida Public Records Law Chapter 119, including specifically those contractual requirements at F.S. § 119.0701(2)(a)-(b) as stated as follows: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: 3 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 Communication and Customer Relations Division 3299 Tamiami Trail East, Suite 102 Naples, FL 34112-5746 Telephone: (239) 252-8383 The Contractor must specifically comply with the Florida Public Records Law to: 1. Keep and maintain public records required by the public agency to perform the service. 2. Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. 3. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the public agency. 4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the Contractor or keep and maintain public records required by the public agency to perform the service. If the Contractor transfers all public records to the public agency upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. 4 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A 17 If Contractor observes that the Contract Documents are at variance therewith, it shall promptly notify the County in writing. Failure by the Contractor to comply with the laws referenced herein shall constitute a breach of this Agreement and the County shall have the discretion to unilaterally terminate this Agreement immediately. In the event of any conflicts in these requirements, the CONSULTANT shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of each such conflict. OWNER'S approval of the design documents in no way relieves CONSULTANT of its obligation to deliver complete and accurate documents necessary for successful construction of the Project. 1.7.1 The County reserves the right to deduct portions of the (monthly) invoiced (task) amount for the following: Tasks not completed within the expressed time frame, including required deliverables, incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements and/or codes and ordinances applicable to Consultant's performance of the work as related to the project. This list is not deemed to be all-inclusive, and the County reserves the right to make sole determination regarding deductions. After notification of deficiency, if the Consultant fails to correct the deficiency within the specified timeframe, these funds would be forfeited by the Consultant. The County may also deduct or charge the Consultant for services and/or items necessary to correct the deficiencies directly related to the Consultant's non-performance whether or not the County obtained substitute performance. 1.8. CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER'S prior written consent, or unless incident to the proper performance of the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its employees, agents, subconsultants and subcontractors to 5 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 comply with the provisions of this paragraph. CONSULTANT shall provide OWNER prompt written notice of any such subpoenas. 1.9 As directed by OWNER, all plans and drawings referencing a specific geographic area must be submitted in an AutoCAD DWG or MicroStation DGN format on a CD or DVD, drawn in the Florida State Plane East (US Feet) Coordinate System (NAD 83/90). The drawings should either reference specific established Survey Monumentation, such as Certified Section Corners (Half or Quarter Sections are also acceptable), or when implemented, derived from the RTK(Real-Time Kinematic) GPS Network as provided by OWNER. Information layers shall have common naming conventions (i.e. right-of-way - ROW, centerlines - CL, edge-of-pavement - EOP, etc), and adhere to industry standard CAD specifications. ARTICLE TWO ADDITIONAL SERVICES OF CONSULTANT If authorized in writing by OWNER through a Change Order or Amendment to this Agreement, CONSULTANT shall furnish or obtain from others Additional Services of the types listed in Article Two herein. The agreed upon scope, compensation and schedule for Additional Services shall be set forth in the Change Order or Amendment authorizing those Additional Services. With respect to the individuals with authority to authorize Additional Services under this Agreement, such authority will be as established in OWNER'S Procurement Ordinance and Procedures in effect at the time such services are authorized. These services will be paid for by OWNER as indicated in Article Five and Schedule B. Except in an emergency endangering life or property, any Additional Services must be approved in writing via a Change Order or an Amendment to this Agreement prior to starting such services. OWNER will not be responsible for the costs of Additional Services commenced without such express prior written approval. Failure to obtain such prior written approval for Additional Services will be deemed: (i) a waiver 6 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 of any claim by CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work is not additional but rather a part of the Basic Services required of CONSULTANT hereunder. If OWNER determines that a change in the Agreement is required because of the action taken by CONSULTANT in response to an emergency, an Amendment shall be issued to document the consequences of the changes or variations, provided that CONSULTANT has delivered written notice to OWNER of the emergency within forty-eight (48) hours from when CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48) hour written notice noted above, waives CONSULTANT'S right it otherwise may have had to seek an adjustment to its compensation or time of performance under this Agreement. The following services, if not otherwise specified in Schedule A as part of Basic Services, shall be Additional Services: 2.1. Preparation of applications and supporting documents (except those already to be furnished under this Agreement) for private or governmental grants, loans, bond issues or advances in connection with the Project. 2.2. Services resulting from significant changes in the general scope, extent or character of the Project or its design including, but not limited to, changes in size, complexity, OWNER'S schedule or character of construction; and revising studies, reports, design documents or Contract Documents previously accepted by OWNER when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to and not reasonably anticipated prior to the preparation of such studies, reports or documents, or are due to any other causes beyond CONSULTANT'S control and fault. 2.3 Providing renderings or models for OWNER'S use. 2.4 Investigations and studies involving detailed consideration of operations, maintenance and overhead expenses; the preparation of feasibility studies, cash flow and economic 7 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. Od 16A 17 evaluations, rate schedules and appraisals; and evaluating processes available for licensing and assisting OWNER in obtaining such process licensing. 2.5. Furnishing services of independent professional associates and consultants for other than the Basic Services to be provided by CONSULTANT hereunder. 2.6. Services during travel outside of Collier and Lee Counties required of CONSULTANT and directed by OWNER, other than visits to the Project site or OWNER's office. 2.7 Preparation of operating, maintenance and staffing manuals, except as otherwise provided for herein. 2.8. Preparing to serve or serving as a CONSULTANT or witness for OWNER in any litigation, or other legal or administrative proceeding, involving the Project (except for assistance in consultations which are included as part of the Basic Services to be provided herein). 2.9 Additional services rendered by CONSULTANT in connection with the Project, not otherwise provided for in this Agreement or not customarily furnished in Collier County as part of the Basic Services in accordance with generally accepted professional practice. ARTICLE THREE OWNER'S RESPONSIBILITIES 3.1. The OWNER shall designate in writing a project manager to act as OWNER'S representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to transmit instructions, receive information, interpret and define OWNER'S policies and decisions with respect to CONSULTANT'S services for the Project. However, the Project Manager is not authorized to issue any verbal or written orders or instructions to the CONSULTANT that would 8 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16 A 1 7 have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONSULTANT hereunder; (b) The time the CONSULTANT is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONSULTANT. 3.2. The Project Manager shall: (a) Review and make appropriate recommendations on all requests submitted by the CONSULTANT for payment for services and work provided and performed in accordance with this Agreement; (b) Provide all criteria and information requested by CONSULTANT as to OWNER's requirements for the Project, including design objectives and constraints, space, capacity and performance requirements, flexibility and expandability, and any budgetary limitations; (c) Upon request from CONSULTANT, assist CONSULTANT by placing at CONSULTANT'S disposal all available information in the OWNER'S possession pertinent to the Project, including existing drawings, specifications, shop drawings, product literature, previous reports and any other data relative to the Project; (d) Arrange for access to and make all provisions for CONSULTANT to enter the Project site to perform the services to be provided by CONSULTANT under this Agreement; and (e) Provide notice to CONSULTANT of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONSULTANT hereunder. 9 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. • 1 6 A 17 ARTICLE FOUR TIME 4.1. Services to be rendered by CONSULTANT shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed in accordance with the Project Milestone Schedule attached hereto and made a part hereof as Schedule C. Time is of the essence with respect to the performance of this Agreement. 4.2. Should CONSULTANT be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONSULTANT shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right which CONSULTANT may have had to request a time extension for that specific delay. 4.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONSULTANT'S services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or additional compensation from OWNER. CONSULTANT'S sole remedy against OWNER will be the right to seek an extension of time to its schedule provided, however, the granting of any such time extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of CONSULTANT, the services to be provided hereunder have been delayed for a total of 180 calendar days, CONSULTANT'S compensation 10 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 0 16A17 shall be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONSULTANT, if any, as a result of such delays. 4.4 Should the CONSULTANT fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONSULTANT until such time as the CONSULTANT resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONSULTANT'S performance is or will shortly be back on schedule. 4.5 In no event shall any approval by OWNER authorizing CONSULTANT to continue performing Work under this Agreement or any payment issued by OWNER to CONSULTANT be deemed a waiver of any right or claim OWNER may have against CONSULTANT for delay or any other damages hereunder. ARTICLE FIVE COMPENSATION 5.1. Compensation and the manner of payment of such compensation by the OWNER for services rendered hereunder by CONSULTANT shall be as prescribed in Schedule B, entitled "Basis of Compensation", which is attached hereto and made a part hereof. The Project Manager, or designee, reserves the right to utilize any of the following Price Methodologies: Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred from the County to the Consultant; and, as a business practice there are no hourly or material invoices presented, rather, the Consultant must perform to the satisfaction of the County's project manager before payment for the fixed price contract is authorized. 11 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 Time and Materials: the County agrees to pay the contractor for the amount of labor time spent by the Consultant 's employees and subcontractors to perform the work (number of hours times hourly rate), and for materials and equipment used in the project (cost of materials plus the contractor's mark up). This methodology is generally used in projects in which it is not possible to accurately estimate the size of the project, or when it is expected that the project requirements would most likely change. As a general business practice, these contracts include back-up documentation of costs; invoices would include number of hours worked and billing rate by position (and not company (or subcontractor) timekeeping or payroll records), material or equipment invoices, and other reimbursable documentation for the project. 5.2. The hourly rates as set forth and identified in Schedule B, which is attached hereto, shall apply only to tasks procured under the Time and Materials pricing methodology specified in paragraph 5.1 above. ARTICLE SIX OWNERSHIP OF DOCUMENTS 6.1. Upon the completion or termination of this Agreement, as directed by OWNER, CONSULTANT shall deliver to OWNER copies or originals of all records, documents, drawings, notes, tracings, plans, MicroStation or AutoCAD files, specifications, maps, evaluations, reports and other technical data, other than working papers, prepared or developed by or for CONSULTANT under this Agreement ("Project Documents"). OWNER shall specify whether the originals or copies of such Project Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all costs associated with delivering to OWNER the Project Documents. CONSULTANT, at its own expense, may retain copies of the Project Documents for its files and internal use. 6.2. Notwithstanding anything in this Agreement to the contrary and without requiring OWNER to pay any additional compensation, CONSULTANT hereby grants to OWNER a nonexclusive, irrevocable license in all of the Project Documents for OWNER'S use on this Project. CONSULTANT warrants to OWNER that it has full right and authority to grant this license to 12 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 1 7 OWNER. Further, CONSULTANT consents to OWNER'S use of the Project Documents to complete the Project following CONSULTANT'S termination for any reason or to perform additions to or remodeling, replacement or renovations of the Project. CONSULTANT also acknowledges OWNER may be making Project Documents available for review and information to various third parties and hereby consents to such use by OWNER. ARTICLE SEVEN MAINTENANCE OF RECORDS 7.1. CONSULTANT will keep adequate records and supporting documentation which concern or reflect its services hereunder. The records and documentation will be retained by CONSULTANT for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the Project is completed, whichever is later, or such later date as may be required by law. OWNER, or any duly authorized agents or representatives of OWNER, shall, free of charge, have the right to audit, inspect and copy all such records and documentation as often as they deem necessary during the period of this Agreement and during the five (5) year period noted above, or such later date as may be required by law; provided, however, such activity shall be conducted only during normal business hours. ARTICLE EIGHT INDEMNIFICATION 8.1. To the maximum extent permitted by Florida law, CONSULTANT shall indemnify and hold harmless OWNER, its officers and employees from any and all liabilities, damages, losses and costs, including, but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may be available to an indemnified party or person described in this paragraph. 13 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 17 ARTICLE NINE INSURANCE 9.1. CONSULTANT shall obtain and carry, at all times during its performance under the Contract Documents, insurance of the types and in the amounts set forth in SCHEDULE D to this Agreement. 9.2 All insurance shall be from responsible companies duly authorized to do business in the State of Florida. 9.3 All insurance policies required by this Agreement shall include the following provisions and conditions by endorsement to the policies: 9.3.1. All insurance policies, other than the Business Automobile policy, Professional Liability policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of this Agreement shall name Collier County Government, Collier County, Florida, as an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a severability of interests provisions. 9.3.2. Companies issuing the insurance policy or policies shall have no recourse against OWNER for payment of premiums or assessments for any deductibles which all are at the sole responsibility and risk of CONSULTANT. 9.3.3. All insurance coverage of CONSULTANT shall be primary to any insurance or self- insurance program carried by OWNER applicable to this Project, and the "Other Insurance" provisions of any policies obtained by CONSULTANT shall not apply to any insurance or self-insurance program carried by OWNER applicable to this Project. 9.3.4. The Certificates of Insurance must read: For any and all work performed on behalf of Collier County, or reference this contract number. 9.3.5. All insurance policies shall be fully performable in Collier County, Florida, and shall be construed in accordance with the laws of the State of Florida. 14 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 17 9.4. CONSULTANT, its subconsultants and OWNER shall waive all rights against each other for damages covered by insurance to the extent insurance proceeds are paid and received by OWNER, except such rights as they may have to the proceeds of such insurance held by any of them. 9.5 All insurance companies from whom CONSULTANT obtains the insurance policies required hereunder must meet the following minimum requirements: 9.5.1. The insurance company must be duly licensed and authorized by the Department of Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida. 9.5.2. The insurance company must have a current A. M. Best financial rating of "Class VI" or higher. ARTICLE TEN SERVICES BY CONSULTANT'S OWN STAFF 10.1. The services to be performed hereunder shall be performed by CONSULTANT'S own staff, unless otherwise authorized in writing by the OWNER. The employment of, contract with, or use of the services of any other person or firm by CONSULTANT, as independent consultant or otherwise, shall be subject to the prior written approval of the OWNER. No provision of this Agreement shall, however, be construed as constituting an agreement between the OWNER and any such other person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third party any claim or right of action against the OWNER beyond such as may then otherwise exist without regard to this Agreement. 10.2 Attached as Schedule F is a listing of all key personnel CONSULTANT intends to assign to the Project to perform the Services required hereunder. Such personnel shall be committed to this Project in accordance with the percentages noted in Schedule F. CONSULTANT also has identified each subconsultant and subcontractor it intends to utilize on the Project in 15 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inca 16A17 Schedule F. All personnel, subconsultants and subcontractors identified in Schedule F shall not be removed or replaced without OWNER'S prior written consent. 10.3 CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors. By appropriate written agreement, the CONSULTANT shall require each subconsultant or subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to be bound to the CONSULTANT by the terms of this Agreement, and to assume toward the CONSULTANT all the obligations and responsibilities which the CONSULTANT, by this Agreement, assumes toward the OWNER. Each subconsultant or subcontract agreement shall preserve and protect the rights of the OWNER under this Agreement with respect to the Services to be performed by the subconsultant or subcontractor so that the subconsulting or subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall require each subconsultant or subcontractor to enter into similar agreements with its sub-subconsultants or sub-subcontractors. 10.4 CONSULTANT acknowledges and agrees that OWNER is a third party beneficiary of each contract entered into between CONSULTANT and each subconsultant or subcontractor, however nothing in this Agreement shall be construed to create any contractual relationship between OWNER and any subconsultant or subcontractor. Further, all such contracts shall provide that, at Owner's discretion, they are assignable to OWNER upon any termination of this Agreement. ARTICLE ELEVEN WAIVER OF CLAIMS 11.1. CONSULTANT'S acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against OWNER arising out of 16 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 17 this Agreement or otherwise related to the Project, and except those previously made in writing in accordance with the terms of this Agreement and identified by CONSULTANT as unsettled at the time of the final payment. Neither the acceptance of CONSULTANT'S services nor payment by OWNER shall be deemed to be a waiver of any of OWNER'S rights against CONSULTANT. ARTICLE TWELVE TERMINATION OR SUSPENSION 12.1. CONSULTANT shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) CONSULTANT'S failure to begin services under the Agreement within the times specified under the Notice(s) to Proceed, or (b) CONSULTANT'S failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT'S principals, officers or directors, or (d) CONSULTANT'S failure to obey any laws, ordinances, regulations or other codes of conduct, or (e) CONSULTANT'S failure to perform or abide by the terms and conditions of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONSULTANT seven (7) calendar days written notice of the material default. 12.2. If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is determined for any reason that CONSULTANT was not in default, or that its default was excusable, or that OWNER otherwise was not entitled to the remedy against CONSULTANT provided for in paragraph 12.1, then the notice of termination given pursuant to paragraph 12.1 shall be deemed to be the notice of termination provided for in paragraph 12.3, below, and CONSULTANT's remedies against OWNER shall be the same as and be limited to those afforded CONSULTANT under paragraph 12.3, below. 17 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 1 7 12.3. OWNER shall have the right to terminate this Agreement, in whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the event of such termination for convenience, CONSULTANT'S recovery against OWNER shall be limited to that portion of the fee earned through the date of termination, together with any retainage withheld and any costs reasonably incurred by CONSULTANT that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or further recovery against OWNER, including, but not limited to, anticipated fees or profits on work not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent reasonably possible. 12.4. Upon termination and as directed by Owner, the CONSULTANT shall deliver to the OWNER all original papers, records, documents, drawings, models, and other material set forth and described in this Agreement, including those described in Section 6, that are in CONSULTANT'S possession or under its control. 12.5. The OWNER shall have the power to suspend all or any portions of the services to be provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written notice of such suspension. If all or any portion of the services to be rendered hereunder are so suspended, the CONSULTANT'S sole and exclusive remedy shall be to seek an extension of time to its schedule in accordance with the procedures set forth in Article Four herein. 12.6 In the event (i) OWNER fails to make any undisputed payment to CONSULTANT within forty-five (45) days after such payment is due or such other time as required by Florida's Prompt Payment Act or (ii) OWNER otherwise persistently fails to fulfill some material obligation owed by OWNER to CONSULTANT under this Agreement, and (ii) OWNER has failed to cure such default within fourteen (14) days of receiving written notice of same from CONSULTANT, then CONSULTANT may stop its performance under this Agreement until such default is cured, after 18 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 giving OWNER a second fourteen (14) days written notice of CONSULTANT's intention to stop performance under the Agreement. If the Services are so stopped for a period of one hundred and twenty (120) consecutive days through no act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees or any other persons performing portions of the Services under contract with the CONSULTANT, the CONSULTANT may terminate this Agreement by giving written notice to OWNER of CONSULTANT'S intent to terminate this Agreement. If OWNER does not cure its default within fourteen (14) days after receipt of CONSULTANT'S written notice, CONSULTANT may, upon fourteen (14) additional days' written notice to the OWNER, terminate the Agreement and recover from the Owner payment for Services performed through the termination date, but in no event shall CONSULTANT be entitled to payment for Services not performed or any other damages from Owner. ARTICLE THIRTEEN TRUTH IN NEGOTIATION REPRESENTATIONS 13.1. CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. 13.2. In accordance with provisions of Section 287.055, (5)(a), Florida Statutes, the CONSULTANT agrees to execute the required Truth-In-Negotiation Certificate, attached hereto and incorporated herein as Schedule E, certifying that wage rates and other factual unit costs supporting the compensation for CONSULTANT'S services to be provided under this Agreement are accurate, complete and current at the time of the Agreement. The CONSULTANT agrees that the original Agreement price and any additions thereto shall be 19 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16 A 17 adjusted to exclude any significant sums by which the OWNER determines the Agreement price was increased due to inaccurate, incomplete, or non-current wage rates and other factual unit costs. All such adjustments shall be made within one (1) year following the end of this Agreement. ARTICLE FOURTEEN CONFLICT OF INTEREST 14.1. CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder. CONSULTANT further represents that no persons having any such interest shall be employed to perform those services. ARTICLE FIFTEEN MODIFICATION 15.1. No modification or change in this Agreement shall be valid or binding upon either party unless in writing and executed by the party or parties intended to be bound by it. ARTICLE SIXTEEN NOTICES AND ADDRESS OF RECORD 16.1. All notices required or made pursuant to this Agreement to be given by the CONSULTANT to the OWNER shall be in writing and shall be delivered by hand, by fax, or by United States Postal Service Department, first class mail service, postage prepaid, addressed to the following OWNER'S address of record: Board of County Commissioners Collier County Florida Procurement Services Division 3327 Tamiami Trail East Naples, FL 34112 Attention: Joanne Markiewicz, Director, Procurement Services Division Telephone: 239-252-8407 Fax: 239-252-6480 20 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16 A 17 16.2. All notices required or made pursuant to this Agreement to be given by the OWNER to the CONSULTANT shall be made in writing and shall be delivered by hand, by fax or by the United States Postal Service Department, first class mail service, postage prepaid, addressed to the following CONSULTANT'S address of record: AECOM Technical Services, Inc. 4415 Metro Parkway, Suite 404 Fort Myers, Florida 33916 Phone: 239-278-7996; Fax: 239-278-0913 Attn: Crystal Gorman, PE, Project Manager 16.3. Either party may change its address of record by written notice to the other party given in accordance with requirements of this Article. ARTICLE SEVENTEEN MISCELLANEOUS 17.1. CONSULTANT, in representing OWNER, shall promote the best interests of OWNER and assume towards OWNER a duty of the highest trust, confidence, and fair dealing. 17.2. No modification, waiver, suspension or termination of the Agreement or of any terms thereof shall impair the rights or liabilities of either party. 17.3. This Agreement is not assignable, or otherwise transferable in whole or in part, by CONSULTANT without the prior written consent of OWNER. 17.4. Waivers by either party of a breach of any provision of this Agreement shall not be deemed to be a waiver of any other breach and shall not be construed to be a modification of the terms of this Agreement. 21 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 17.5. The headings of the Articles, Schedules, Parts and Attachments as contained in this Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or change the provisions in such Articles, Schedules, Parts and Attachments. 17.6. This Agreement, including the referenced Schedules and Attachments hereto, constitutes the entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior agreements or understandings, written or oral, relating to the matter set forth herein, and any such prior agreements or understanding shall have no force or effect whatever on this Agreement. 17.7 Unless otherwise expressly noted herein, all representations and covenants of the parties shall survive the expiration or termination of this Agreement. 17.8 This Agreement may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. 17.9 The terms and conditions of the following Schedules attached hereto are by this reference incorporated herein: Schedule A SCOPE OF SERVICES Schedule B BASIS OF COMPENSATION Schedule C PROJECT MILESTONE SCHEDULE Schedule D INSURANCE COVERAGE Schedule E TRUTH IN NEGOTIATION CERTIFICATE Schedule F KEY PERSONNEL, SUBCONSULTANTS AND SUBCONTRACTORS RFP # 15-6418 CEI Services for Vanderbilt Drive, Terms and Conditions Consultant's Proposal 22 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. ��O ARTICLE EIGHTEEN 16A17 APPLICABLE LAW 18.1. This Agreement shall be governed by the laws, rules, and regulations of the State of Florida, and by such laws, rules and regulations of the United States as made applicable to services funded by the United States government. Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. ARTICLE NINETEEN SECURING AGREEMENT/PUBLIC ENTITY CRIMES 19.1 CONSULTANT warrants that CONSULTANT has not employed or retained any company or person, other than a bona fide employee working solely for CONSULTANT, to solicit or secure this Agreement and that CONSULTANT has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for CONSULTANT, any fee, commission, percentage, gift or any other consideration contingent upon or resulting from the award or making of this Agreement. At the time this Agreement is executed, CONSULTANT shall sign and deliver to OWNER the Truth-In-Negotiation Certificate identified in Article 13 and attached hereto and made a part hereof as Schedule E. CONSULTANT'S compensation shall be adjusted to exclude any sums by which OWNER determines the compensation was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 19.2 By its execution of this Agreement, CONSULTANT acknowledges that it has been informed by OWNER of and is in compliance with the terms of Section 287.133(2)(a) of the Florida Statutes which read as follows: "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may 23 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, In_ 6 16A17 not submit bids, proposals, or replies on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." ARTICLE TWENTY DISPUTE RESOLUTION 20.1 Prior to the initiation of any action or proceeding permitted by this Agreement to resolve disputes between the parties, the parties shall make a good faith effort to resolve any such disputes by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached during negotiations to OWNER for approval. Failing resolution, and prior to the commencement of depositions in any litigation between the parties arising out of this Agreement, the parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State of Florida. The mediation shall be attended by representatives of CONSULTANT with full decision-making authority and by OWNER'S staff person who would make the presentation of any settlement reached at mediation to OWNER'S board for approval. Should either party fail to submit to mediation as required hereunder, the other party may obtain a court order requiring mediation under section 44.102, Fla. Stat. 20.2 Any suit or action brought by either party to this Agreement against the other party relating to or arising out of this Agreement must be brought in the appropriate federal or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such matters. 24 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc' �0 G 16A17 ARTICLE 21 IMMIGRATION LAW COMPLIANCE 21.1 By executing and entering into this agreement, the CONSULTANT is formally acknowledging without exception or stipulation that it is fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws referenced herein shall constitute a breach of this agreement and the County shall have the discretion to unilaterally terminate this agreement immediately. ********** 25 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inco 16A17 IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement for CEI Services the day and year first written above. ATTEST: BOARD OF COUNTY COMMISSIONERS FOR COLLIER COUNTY, FLORIDA, Dwight E. Brodk, Clerk By: ' \VW'LA 41- 1 �1- MI letcp, V. Date:d0U1,1 2:10,110By: 41'010 Attest as to Charmans ' Donna Fiala, Chairman signature only. A,: •ro ed as to, r and Legality: A— L_____ ‘.-- -ttt-County Attorney p _ 3 � i2 ,eQ & Name AECOM Technical Services, Inc. (II - By: / WW itne��s 15i-cd GOrrriCtfl/5r. ProjeG-t- r,g. 1 . t. A. .e..� slcu L$ w I A 1024 c w 44 Name and Title Name and Title 14-011q laark-ows6 , A4s Ars4- LI titAl witi A<J2_0Aktiglig jci • Name and Tithe 26 "I Agreement#15-6418"Vanderbilt Drive Bridge Replacement" op AECOM Technical Services, Inc. 16A11 SCHEDULE A SCOPE OF SERVICES SCOPE OF SERVICES Project Description: The principal intent of this project is to provide CEI and Related Services for the replacement of two existing functionally obsolete bridges (#030177 and #030178), relocation of an existing pedestrian bridge, road resurfacing/reconstruction, utility relocation, intersection reconstruction and multiuse pathway construction on Vanderbilt Drive. County Project Number: 66066.11. 1.0 PURPOSE: This scope of services describes and defines the Construction Engineering and Inspection (CEI) services which are required for contract administration, inspection, and materials sampling and testing for each of the construction project listed below. 2.0 SCOPE: Provide services as defined in this Scope of Services, the referenced Florida Department of Transportation (FDOT) manuals, and procedures. The project for which the services are required is: County Project Number: 66066.11 Descriptions: The principal intent of this project is to provide CEI and Related Services for the replacement of two existing functionally obsolete bridges (#030177 and #030178), relocation of an existing pedestrian bridge, utility relocation, road resurfacing/reconstruction, intersection reconstruction and multiuse pathway construction along Vanderbilt Drive. The Consultant and/or Sub-consultant(s) must be FDOT qualified (Rule Chapter 14-75) to perform the assigned work and/or services required of the project. As a minimum, the Consultant must be qualified to perform the following types of work: • 10.1 — Roadway CEI • 10.3 — Construction Materials Inspection • 10.4 — Minor Bridge and Miscellaneous Structures CEI Exceptions to these minimum types of work qualifications may be considered at the discretion of the County. Any exceptions to these minimum types of work qualifications must be preapproved by the County in writing. D-1 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 41? 16A17 Exercise independent professional judgment in performing obligations and responsibilities under this Agreement. Pursuant to Section 4.1.4 of the Construction Project Administration Manual (CPAM), the authority of the Consultant's lead person, such as the Senior Project Engineer, and the Consultant's Project Administrator shall be identical to the FDOT's Resident Engineer and Project Administrator respectively and shall be interpreted as such. Services provided by the Consultant shall comply with FDOT manuals, procedures, and memorandums in effect as of the date of execution of the Agreement unless otherwise directed in writing by the County. Such FDOT manuals, procedures, and memorandums are found at the State Construction Office's website. On a single Construction Contract, it is a conflict of interest for a professional firm to receive compensation from both the County and the Contractor either directly or indirectly. Other projects developing within the geographical area of Collier County may be added at the County's discretion. The Consultant must perform to the satisfaction of the County's representatives for consideration of additional CEI services. 3.0 LENGTH OF SERVICE: The services for the Construction Contract shall begin upon written notification to proceed (NTP) by the County. The CEI Services Contract shall begin approximately thirty (30) days prior to written notification to proceed to the Contractor for the Construction Contract and end thirty (30) days after final acceptance of the Construction Contract. The County's Construction Project Manager will track the execution of the Construction Contract such that the Consultant is given timely authorization to begin work. While no personnel shall be assigned until written notification by the County has been issued, the Consultant shall be ready to assign personnel within two weeks of notification. For the duration of the project, coordinate closely with the County and Contractor to minimize rescheduling of Consultant activities due to construction delays or changes in scheduling of Contractor activities. For estimating purposes, the Consultant will be allowed an accumulation of thirty (30) calendar days to perform preliminary administrative services prior to the issuance of the Contractor's notice to proceed on the first project and thirty (30) calendar days to demobilize after final acceptance of the Construction Contract. D-2 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 The anticipated letting schedule and construction time for the project is tabulated below: Construction Contract Estimate Financial Start Duration Project ID Date (Days) 66066.11 1st 730 Quarter 2016 4.0 DEFINITIONS: A. Agreement: The Professional Services Agreement between the County and the Consultant setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of services, and the basis of payment. B. Contractor: The individual, firm, or company contracting with the County for performance of work or furnishing of materials. C. Construction Contract: The written agreement between the County and the Contractor setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of labor and materials, and the basis of payment. D. Construction Project Manager: The County employee assigned to manage the Construction Engineering and Inspection Contract and represent the County during the performance of the services covered under this Agreement. E. Construction Training/Qualification Program (CTQP): The FDOT program for training and qualifying technicians in Aggregates, Asphalt, Concrete, Earthwork, and Final Estimates Administration. Program information is available at CTQP website. F. Consultant: The Consulting firm under contract to the County for administration of Construction Engineering and Inspection services. G. Consultant Project Administrator: The employee assigned by the Consultant to be in charge of providing Construction Contract administration services for the Construction Project. H. Consultant Senior Project Engineer: The Engineer assigned by the Consultant to be in charge of providing Construction Contract administration for the Construction Project. This person may supervise other Consultant employees and act as the lead Engineer for the Consultant. D-3 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 I. Transportation Engineering Director: The administrative head of the County's Construction Offices / The Engineer assigned to administer Construction Contracts for the County. J. County Construction Manager: The County employee assigned to administer the Consultant Construction Engineering and Inspection Program in the County. K. County Professional Services Administrator: The Administrative Head of the Pro- fessional Services Office. L. County Manager: The County Administrator of the County. M. Engineer of Record: The Engineer noted on the Construction plans as the responsible person for the design and preparation of the plans. N. Road Maintenance Director: The County employee assigned to administer Maintenance Contracts for the County. O. Community Liaison: The County employee assigned to manage the Public Information Program. P. Resident Compliance Specialist: The employee assigned by the Consultant to oversee project specific compliance functions. Q. Owner: The Board of County Commissioners for Collier County, Florida. A political subdivision of the State of Florida R. County: Collier County, a political subdivision of the State of Florida. 5.0 ITEMS TO BE FURNISHED BY THE COUNTY TO THE CONSULTANT: A. The County, on an as needed basis, will furnish the following Construction Contract documents for each project. These documents may be provided in either paper (as indicated below) or electronic format. 1. Construction Plans, five (5) [11" x 17"] hard copy sets, 2. Specification Package five (5) [8-1/2" x 111 hard copy sets, 3. One (1) hard copy of the Executed Construction Contract, 4. One (1) hard copy of the Utility Agency's Approved Material List (if applicable), and 5. One (1) hard copy of executed Utility Work Schedules (if applicable). B. A list of all standard forms for use under the terms of this Agreement will be provided in one (1) hard copy or electronic format at the Pre-Services meeting. All directives, procedures, and standard forms can be accessed through the County's website. D-4 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 1 7 6.0 ITEMS FURNISHED BY THE CONSULTANT: 6.1 FDOT Documents: All applicable FDOT documents referenced herein shall be a condition of this Agreement. All FDOT documents, directives, procedures, and standard forms are available through the FDOT's Internet website. Most items can be purchased through the following address. All others can be acquired through the FDOT's District Office or on-line at the FDOT's website. Florida Department of Transportation Maps and Publication Sales 605 Suwannee Street, MS 12 Tallahassee, Florida 32399-0450 Telephone No. (850) 488-9220 http://www.dot.state.fl.us/construction/ 6.2 Office Automation: Provide all software and hardware necessary to efficiently and effectively carry out the responsibilities under this Agreement. Provide each inspection staff with a laptop computer running software (such as, Site Manager application through Citrix, Primavera/Sidetrack, Claim Digger, etc.) for project scheduling, documentation, and control. Each inspection staff laptop computer must have mobile broadband connection at the jobsite. All computer coding shall be input by Consultant personnel using equipment furnished by them. Ownership and possession of computer equipment and related software, which is provided by the Consultant, shall remain at all times with the Consultant. The Consultant shall retain responsibility for risk of loss or damage to said equipment during performance of this Agreement. Field office equipment should be maintained and operational at all times. Current technical specifications for office automation can be viewed at: http://www.dot.state.fl.us/Construction/DesignBuild/ConsultantCEl/OfficeAutomation.shtm 6.3 Field Office: The County may require a field office for this project. The Consultant shall be reimbursed for allowed expenses associated with this field office. The office must have, at a minimum, the following essential items to support the project: D-5 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 0 1 6 A 1 ? • Office space within a desired radius (to be approved by the County) of the project for the duration of the project, • Office telephone, and • Copier rental/lease. Consultant shall list this fixed monthly cost as a line item of the cost proposal titled "Field Office Expenses", and shall also be listed as such on invoices submitted to the County for payment. 6.4 Vehicles: Vehicles will be equipped with appropriate safety equipment and must be able to effectively carry out requirements of this Agreement. Vehicles shall have the name and phone number of the consulting firm visibly displayed on both sides of the vehicle. 6.5 Field Equipment: Supply survey, inspection, and testing equipment essential to perform services under this Agreement; such equipment includes non-consumable and non- expendable items. Hard hats shall have the name of the consulting firm visibly displayed. Equipment described herein and expendable materials under this Agreement will remain the property of the Consultant and shall be removed at completion of the work. Handling of nuclear density gauges shall be in compliance with their license. Retain responsibility for risk of loss or damage to said equipment during performance of this Agreement. Field office equipment shall be maintained and in operational condition at all times. 6.6 Licensing for Equipment Operations: Obtain proper licenses for equipment and personnel operating equipment when licenses are required. The license and supporting documents shall be available for verification by the County, upon request. Radioactive Materials License for use of Surface Moisture Density Gauges shall be obtained through the State of Florida Department of Health. 7.0 LIAISON RESPONSIBILITY OF THE CONSULTANT: For the duration of the Agreement, keep the County's Construction Project Manager in Responsible Charge informed of all significant activities, decisions, correspondence, reports, and other communications related to its responsibilities under this Agreement. D-6 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 Facilitate communications between all parties (i.e. architectural, mechanical, materials, landscaping, local agencies, etc.) ensuring responses and resolutions are provided in a timely manner. Maintain accurate records to document the communication process. Submit all administrative items relating to Invoice Approval, Personnel Approval, User IDs, Time Extensions, and Change Orders to the County's Construction Project Manager for review and approval. 8.0 PERFORMANCE OF THE CONSULTANT: During the term of this Agreement and all Change Orders thereof, the County will review various phases of Consultant operations, such as construction inspection, materials sampling and testing, and administrative activities, to determine compliance with this Agreement. Cooperate and assist County representatives in conducting the reviews. If deficiencies are indicated, remedial action shall be implemented immediately. County recommendations and Consultant responses/actions are to be properly documented by the Consultant. No additional compensation shall be allowed for remedial action taken by the Consultant to correct deficiencies. Remedial actions and required response times may include but are not necessarily limited to the following: A. Further subdivide assigned inspection responsibilities, reassign inspection personnel, or assign additional inspection personnel, within one week of notification. B. Immediately replace personnel whose performance has been determined by the Consultant and/or the County to be inadequate. C. Immediately increase the frequency of monitoring and inspection activities in phases of work that are the Consultant's responsibility. D. Increase the scope and frequency of training of the Consultant personnel. 9.0 REQUIREMENTS OF THE CONSULTANT: 9.1 General: It shall be the responsibility of the Consultant to administer, monitor, and inspect the Construction Contract such that the project is constructed in reasonable conformity with the plans, specifications, and special provisions for the Construction Contract. Observe the Contractor's work to determine the progress and quality of work. Identify discrepancies, report significant discrepancies to the County, and direct the Contractor to correct such observed discrepancies. Consult with the County's Construction Project Manager as necessary and direct all issues, which exceed delegated authority to the County's Construction Project Manager for County action or direction. D-7 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 17 Inform the County's Construction Project Manager of any significant omis- sions, substitutions, defects, and deficiencies noted in the work of the Contractor and the corrective action that has been directed to be performed by the Contractor. For the duration of the project, all Technicians and Inspector provided by the Consultant and/or Sub-Consultant(s) for the project must be CTQP qualified to perform the assigned duties and/or tasks. 9.2 Survey Control: Check or establish the survey control baseline(s) along with sufficient baseline control points and bench marks at appropriate intervals along the project in order to: (1) make and record measurements necessary to calculate and document quantities for pay items, (2) make and record pre-construction and final cross section surveys of the project site in those areas where earthwork (i.e., embankment, excavation, subsoil excavation, etc.) is part of the construction project, and (3) perform incidental engineering surveys. 9.3 On-site Inspection: Monitor the Contractor's on-site construction activities and inspect materials entering into the work in accordance with the plans, specifications, and special provisions for the Construction Contract to determine that the project is constructed in reasonable conformity with such documents. Maintain detailed accurate records of the Contractor's daily operations and of significant events that affect the work. The Consultant will monitor off-site activities and fabrication unless otherwise stipulated by this Agreement. Perform underwater bridge construction inspections of bridges with permanently submerged structural members in compliance with CPAM Section 10.6, Underwater Bridge Construction Inspection. Monitor and inspect Contractor's Work Zone Traffic Control Plan and review modifications to the Work Zone Traffic Control Plan, including Alternate Work Zone Traffic Control Plan, in accordance with the FDOT's procedures. Consultant employees performing such services shall be qualified in accordance with the FDOT's guidelines of Traffic Training (Topic No. 625-010-010-h). 9.4 Sampling and Testing: Perform sampling and testing of component materials and completed work in accordance with the Construction Contract documents. All sampling and testing shall be executed in conjunction with a licensed independent laboratory, hired by the Consultant, that is approved in writing by the County's Construction Project Manager. The minimum sampling frequencies set out in the FDOT's Materials Sampling, Testing and Reporting Guide shall be met. In complying with the aforementioned guide, provide daily surveillance of the Contractor's Quality D-8 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 Control activities and perform the sampling and testing of materials and completed work items for verification and acceptance. The Consultant will perform inspection and sampling of materials and components at locations remote from the project site and perform testing of materials normally done in a laboratory remote from the project site. Determine the acceptability of all materials and completed work items on the basis of either test results or verification of a certification, certified mill analysis, DOT label, DOT stamp, etc. The County will monitor the effectiveness of the Consultant's testing procedures through observation and independent assurance testing. Sampling, testing and laboratory methods shall be as required by the FDOT's Standard Specifications, Supplemental Specifications or as modified by the Special Provisions of the Construction Contract. Documentation reports on sampling and testing performed by the Consultant shall be submitted during the same week that the construction work is done. Transport samples to the appropriate laboratory. The Consultant shall provide daily surveillance of the Contractor's Quality Control activities at the project site in regard to concrete and perform acceptance testing and sampling. 9.5 Engineering Services: While under contract with the County, the Consultant will, coordinate the Construction Contract administration activities of all parties other than the Contractor involved in completing the construction project. Services shall include maintaining the required level of surveillance of Contractor activities, interpreting plans, specifications, and special provisions for the Construction Contract. Maintain complete, accurate records of all activities and events relating to the project and properly document all project changes. The following services shall be performed: (1) Attend a pre-service meeting for the Agreement in accordance with CPAM. Provide appropriate staff to attend and participate in the pre-service meeting. At the pre-service meeting the Consultant shall submit Action Request packages for Personnel Approval for immediate staff needs and a copy/computer file of the final negotiated staffing. The Consultant shall record a complete and concise record of the proceedings of the meeting and distribute copies of these minutes to the participants and other interested parties within seven (7) days of the meeting date. (2) Prepare and submit to the County's Construction Project Manager for county approval, within thirty (30) days after the pre-service meeting, a hard D-9 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. Clo) I 16A17 copy of the project specific Consultant Contract administration documents listed below. The Consultant Contract administration documents, which shall be routinely used by the Consultant throughout the project, shall be in the format and content provided by the County Construction Management Department. The CONSULTANT Contract administration documents consist of but are not limited to: a. Action Request Form, b. Contract Status Report, or other approved fund tracking report, c. CEI CONSULTANT Firm Estimated Staffing (completed in accordance with the original CONSULTANT Contract agreement), d. CEI CONSULTANT Fee Proposal, and e. CEI CONSULTANT Data. (3) Schedule and conduct a Pre-construction conference in accordance with Article 8-3.5 of the FDOT Standard Specification for Road and Bridge Construction. The purpose of these meetings is to discuss the required documentation, including as-builts, necessary for permit(s) compliance. Record significant information revealed and decisions made at this conference and distribute copies of these minutes to the appropriate parties. The meeting shall also be electronically recorded and the Consultant shall maintain all tapes of the meeting for the duration of the Contract. (4) Verify that the Contractor is conducting inspections, preparing reports and monitoring all storm water pollution prevention measures associated with the project. For each project that requires the use of the NPDES General Permit, provide at least one inspector who has successfully completed the "Florida Stormwater, Erosion, and Sedimentation Control Training and Certification Program for Inspectors and Contractors". The Consultant's inspector will be familiar with the requirements set forth in the FEDERAL REGISTER, Vol. 57, No. 187, Friday, September 5, 1992, pages 4412 to 4435 "Final NPDES General Permits for Storm Water Discharges from Construction Sites" and the FDOT's guidelines. (5) Analyze the Contractor's schedule(s) (i.e. baseline(s), revised baseline(s), updates, as-built, etc.) for compliance with the contract documents. Elements including, but not limited to, completeness, logic, durations, activity, flow, milestone dates, concurrency, resource allotment, and delays will be reviewed. Verify the schedule conforms with the construction phasing and MOT sequences, including all contract modifications. Provide a written review of the schedule identifying significant omissions, improbable or unreasonable activity durations, errors in logic, and any other concerns as detailed in CPAM. D-10 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Secvi s, Inc. ('il® 1 6 A 17 (6) Analyze problems that arise on a project and proposals submitted by the Contractor; work to resolve such issues, and process the necessary paperwork. (7) Monitor, inspect and document utility construction for conformance with Utility Agency's Standards and the Utility Agency's Approved Materials List. Facilitate coordination and communication between Utility Agency's representatives, County's staff and Contractors executing the work. Identify potential utility conflicts and assist in the resolution of utility issues including County and Local Government owned facilities. Identify, review, and track progress of Joint Project Agreements, and/or other County and utility agreements if applicable. Address work progress, track reimbursement activities, and address betterment and salvage determination. Prepare all necessary documentation to support reimbursement activities and betterment and salvage determination. (8) Produce reports, verify quantity calculations and field measure for payment purposes as needed to prevent delays in Contractor operations and to facilitate prompt processing of such information in order for the County to make timely payment to the Contractor. (9) Prepare and make presentations for meetings and hearings before the Dispute Review Boards in connection with the project covered by this Agreement. (10) Monitor each Contractor and Subcontractor's compliance with specifications and special provisions of the Construction Contract in regard to payment in accordance with County procedures. (11) The County will provide Public Information Services. (12) Video tape the pre-construction conditions throughout the project limits. Provide a digital photo log or video of project activities, with heavy emphasis on potential claim items/issues and on areas of real/potential public controversy. (13) Provide a digital camera for photographic documentation of pre- construction state and of noteworthy incidents or events during construction. These photographs will be filed and maintained on the Consultant's computer using a Digital Photo Management system. Photographs shall be taken the day prior to the start of construction and continue as needed throughout the project. Photographs shall be taken the days of Conditional, Partial and Final Acceptance. D-11 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 9.6 Geotechnical Engineering: The prime Consultant may engage the services of a geotechnical subconsultant to perform some of the services indicated in this section. However, the prime Consultant will be responsible to the County for the satisfactory performance and timeliness of these services. Become familiar with the existing site conditions and the contract documents. Observe and record the progress and quality of foundation work to determine that the foundations are constructed at the correct locations and elevations, identify discrepancies, and direct the Contractor to correct such observed discrepancies. Attend the Preconstruction Conference and/or special geotechnical meeting for the Construction Contract. All services under this section will be performed in accordance to FDOT Specification Section 455. Inspect and verify that the Contractor has performed the foundation work in accordance with applicable FDOT Specification Section 455 and other contract documents. Provide qualified Geotechnical Engineers and CTQP qualified inspectors in Pile Driving inspection, relevant to the foundation type(s) required in the plans. Schedule meetings and facilitate communications between the Contractor and any Specialty Contractors, and the CEI. Observe and verify that all work is performed in accordance with the contract documents. Assure that any specialty work is completed as necessary to accomplish its intent. The following geotechnical engineering services shall be performed: Piles: • Process and review the Pile Installation Plan in accordance with CPAM. • Provide comments regarding the suitability of hammer driving system(s) included in the Pile Installation Plan. • Schedule a pre-pile installation meeting to review and discuss the pile installation procedures. Make sure the Contractor's field superintendent, CEI's pile inspectors, and the County is invited. Prepare and distribute meeting minutes to the attendees. • Inspect and record the test pile driving process in accordance with CPAM. • Inspect the conditions of the piles prior to installation, including any pile splices. • Observe and verify that concrete piles were properly supported during storage and handled with appropriate pick-up details per contract documents. • Inspect the pile driving installation. Complete the FDOT pile driving logs. • Observe the performance of any static or statnamic load tests and review the details are implemented as planned. • Evaluate problems encountered during construction and coordinate with the County and the Contractor to resolve such problems, including possible additional testing and withdrawing the Pile Installation Plan. D-12 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. c90 16A17 10.0 PERSONNEL: 10.1 General Requirements: Provide qualified personnel necessary to efficiently and effectively carry out its responsibilities under this Agreement. Acceptable staffing of personnel to be assigned to this project is outlined herein and in Exhibit "A-A" of the solicitation. Pursuant to Section 4.1.4 of the Construction Project Administration Manual (CPAM), the authority of the Consultant's lead person, such as the Senior Project Engineer, and the Consultant's Project Administrator shall be identical to the FDOT's Resident Engineer and Project Administrator respectively and shall be interpreted as such. FDOT Certification of the Consultant's Project Administrator is a requirement of the contract. 10.2 Personnel Qualifications: Provide competent personnel qualified by experience and education. Submit in writing to the County's Construction Project Manager the names of personnel proposed for assignment to the project, including a detailed resume for each containing at a minimum: salary, education, and experience. The Consultant Action Request form for personnel approval shall be submitted to the County's Construction Project Manager at least two weeks prior to the date an individual is to report to work. Personnel identified in the Consultant technical proposal are to be assigned as proposed and are committed to performing services under this Agreement. Personnel changes will require written approval from the County's Construction Project Manager. Staff that has been removed shall be replaced by the Consultant within one week of County Construction Project Manager's notification. Before the project begins, all project staff shall have a working knowledge of the current CPAM and must possess all the necessary qualifications/certifications for fulfilling the duties of the position they hold. Cross training of the Consultant's project staff is highly recommended to achieve a knowledgeable and versatile project inspection team but shall not be at any additional cost to the County and should occur as workload permits. Visit the training page on the State Construction Office website for training dates. Minimum qualifications for the Consultant personnel are set forth herein and in Exhibit "A-A" of the solicitation. Exceptions to these minimum qualifications may be considered on an individual basis at the discretion of the County. Any exceptions to these minimum qualifications must be preapproved by the County in writing. However, a Project Administrator working under the supervision and direction of a Senior Project Engineer or an Inspector working under the supervision and direction of a Senior Inspector shall have six months from the date of hire to obtain the necessary qualifications/certifications provided all other requirements for such positions are met and the Consultant submits a training plan D-13 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6A 17 detailing when such qualifications/certifications and other training relative to the FDOT's procedures, Specifications and Design Standards will be obtained. The County will have the final approval authority on such exceptions. 10.3 Staffing: Once authorized, the Consultant shall establish and maintain appropriate staffing throughout the duration of construction and completion of the final estimate. Responsible personnel, thoroughly familiar with all aspects of construction and final measurements of the various pay items, shall be available to resolve disputed final pay quantities until the County has received a regular acceptance letter. Construction engineering and inspection forces will be required of the Consultant while the Contractor is working. If Contractor operations are substantially reduced or suspended, the Consultant will reduce its staff appropriately. In the event that the suspension of Contractor operations requires the removal of Consultant forces from the project, the Consultant will be allowed ten (10) days maximum to demobilize, relocate, or terminate such forces. 11.0 QUALITY ASSURANCE (QA) PROGRAM: 11.1 Quality Assurance Plan: Within thirty (30) days after receiving award of an Agreement, furnish a QA Plan to the County's Construction Project Manager. The QA Plan shall detail the procedures, evaluation criteria, and instructions of the Consultant's organization for providing services pursuant to this Agreement. Unless specifically waived, no payment shall be made until the County approves the Consultant QA Plan. Significant changes to the work requirements may require the Consultant to revise the QA Plan. It shall be the responsibility of the Consultant to keep the plan current with the work requirements. The Plan shall include, but not be limited to, the following areas: A. Organization: A description is required of the Consultant QA Organization and its functional relationship to the part of the organization performing the work under the Agreement. The authority, responsibilities and autonomy of the QA organization shall be detailed as well as the names and qualifications of personnel in the quality control organization. B. Quality Assurance Reviews: Detail the methods used to monitor and achieve organization compliance with Agreement requirements for services and products. D-14 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 1 7 C. Quality Assurance Records: Outline the types of records which will be generated and maintained during the execution of the QA program. D. Control of Subconsultants and Vendors: Detail the methods used to control subconsultant and vendor quality. E. Quality Assurance Certification: An officer of the Consultant firm shall certify that the inspection and documentation was done in accordance with FDOT specifications, plans, standard indexes, and FDOT procedures. 11.2 Quality Assurance Reviews: Conduct semi-annual Quality Assurance Reviews to ensure compliance with the requirements of the Agreement. Quality Assurance Reviews shall be conducted to evaluate the adequacy of materials, processes, documentation, procedures, training, guidance, and staffing included in the execution of this Agreement. Quality Assurance Reviews shall also be developed and performed to achieve compliance with specific QA provisions contained in this Agreement. The semi- annual reviews shall be submitted to the County's Construction Project Manager in written form no later than one (1) month after the review. On short duration CCEI projects (nine (9) months or less), the CCEI shall perform an initial QA review within the first two (2) months of the start of construction. On asphalt projects, the CCEI shall perform an initial QA review on its asphalt inspection staff after the Contractor has completed ten (10) full work days of mainline asphalt paving operations, or 25% of the asphalt pay item amount (whichever is less) to validate that all sampling, testing, inspection, and documentation are occurring as required of the CCEI staff. 11.3 Quality Records: Maintain adequate records of the quality assurance actions performed by the organization (including subcontractors and vendors) in providing services and products under this Agreement. All records shall indicate the nature and number of observations made, the number and type of deficiencies found, and the corrective actions taken. All records shall be available to the County, upon request, during the Agreement term. All records shall be kept at the primary job site and shall be subject to audit review. D-15 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 17 12.0 CERTIFICATION OF FINAL ESTIMATES: 12.1 Final Estimate and As-Built Plans Submittal: Prepare documentation and records in compliance with the Agreement, Statewide Quality Control (QC) Plan, or Consultant's approved QC Plan and the FDOT's Procedures as required by Section 4.1.4 of Review and Administration Manual. Submit the Final Estimate(s) and one (1) set of final Signed and Sealed "as-built" documents (including, as applicable, all Signed and Sealed revisions to the contract documents [including but not limited to, all revised drawings, specifications, calculations, technical special provisions, load ratings, etc.]). The "as-built" documents must represent all of the Contractor's work in accordance with the Review and Administration Manual. Revisions to the Certified Final Estimate will be made at no additional cost to the County. 12.2 Certification: Consultant personnel preparing the Certified Final Estimate Package shall be CTQP Final Estimates Level II. Duly authorized representative of the Consultant firm will provide a notarized certification on a form pursuant to FDOT's procedures. 12.3 Offer of Final Payment: Prepare the Offer of Final Payment package as outlined in Chapter 14 of the Review and Administration Manual. The package shall accompany the Certified Final Estimates Package submitted to the County's Construction Project Manager for review. The Consultant shall be responsible for forwarding the Offer of Final Payment Package to the Contractor. 13.0 AGREEMENT MANAGEMENT: 13.1 General: With each monthly invoice submittal, the Consultant will provide a Status Report for the Agreement. This report will provide an accounting of the additional Agreement calendar days allowed to date, an estimate of the additional calendar days anticipated to be added to the original schedule time, an estimate of the Agreement completion date, and an estimate of the Consultant funds expiration date per the Agreement schedule for the prime Consultant and for each subconsultant. The Consultant will provide a printout from the Equal Opportunity Reporting System showing the previous month's payments made to subconsultants. Invoices not including this required information may be rejected. 13.2 Invoicing Instructions: Monthly invoices shall be submitted to the County in a format approved by the County, no later than the 20th day of the month following the month being invoiced. D-16 Agreement#15-6418 Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. PO 1 6 A 17 If the Consultant cannot submit their monthly invoice on time, the Consultant shall notify the County, prior to the due date the reason for the delay and the planned submittal date. Once submitted, the Consultant shall notify the County's Construction Project Manager via Email of the total delay in calendar days and the reason(s) for the delay(s). 14.0 OTHER SERVICES: Upon written authorization by the County's Construction Project Manager, the Consultant will perform additional services in connection with the project not otherwise identified in this Agreement. The following items are not included as part of this Agreement, but may be required by the County to supplement the Consultant services under this Agreement. A. Assist in the timely preparation of all claims and necessary rebuttals with the organization of any and all supporting documentation as needed or required by the County pursuant to the Collier County Alternative Dispute Resolution Procedures. B. Provide qualified engineering witnesses and exhibits for any litigation or hearings in connection with the Contract. C. Assist the County Attorney or his designee as directed in the preparation for Binding Arbitration and Pre-Suit Mediation. D. Provide on- and off-site inspection services in addition to those provided for in this Agreement. 15.0 POST CONSTRUCTION CLAIMS REVIEW: In the event the Consultant for the project submits a claim for additional compensation and/or time after the Consultant has completed this Agreement, the Consultant shall, at the written request from the County, analyze the claim, prepare a recommendation to the County's Construction Project Manager covering validity and reasonableness of charges, and/or assist in negotiations leading to settlement of the claim. Compensation will be separately reimbursed by a Supplement to this Agreement 16.0 COUNTY AUTHORITY The County shall be the final authority in considering modifications to the Construction Contract for time, money or any other consideration except matters agreed to by the Contractor through contract changes negotiated by the Consultant, as authorized in Section 9.1 herein. D-17 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 17 SCHEDULE B BASIS OF COMPENSATION TIME AND MATERIAL 1. MONTHLY STATUS REPORTS B.1.1 As a condition precedent to payment, CONSULTANT shall submit to OWNER as part of its monthly invoice, a progress report reflecting the Project design and construction status, in terms of the total work effort estimated to be required for the completion of the Basic Services and any then-authorized Additional Services, as of the last day of the subject monthly billing cycle. Among other things, the report shall show all Service items and the percentage complete of each item. 2. COMPENSATION TO CONSULTANT B.2.1. For the Basic Services provided for in this Agreement, OWNER agrees to make monthly payments to CONSULTANT based upon CONSULTANT'S Direct Labor Costs and Reimbursable Expenses in accordance with the terms stated below. Provided, however, in no event shall such compensation exceed the amounts set forth in the table below. TASK Description NOT TO EXCEED AMOUNT: A.1 Preconstruction Activities $15,599 A.2 Construction Engineering and Inspection Activities $654,542 A.3 Construction Engineering and Inspections OT $37,328 A.4 Post Construction Activities $21,599 B Not-to-Exceed Fee for Reimbursable Expenses $71,607.45 TOTAL FEE $800,675.45 B.2.2. Direct Labor Costs mean the actual salaries and wages (basic, premium and incentive) paid to CONSULTANT'S personnel, with respect to this Project, including all indirect payroll related costs and fringe benefits, all in accordance with and not in excess of the rates set forth in the Attachment Ito this Schedule B. B.2.3. With each monthly Application for Payment, CONSULTANT shall submit detailed time records, and any other documentation reasonably required by OWNER, regarding CONSULTANT'S Direct Labor Costs incurred at the time of billing, to be reviewed and approved by OWNER. B.2.4 For Additional Services provided pursuant to Article 2 of the Agreement, OWNER agrees to pay CONSULTANT a negotiated total fee and Reimbursable Expenses based on the services to be provided. The negotiated fee shall be based upon the rates specified in Attachment 1 to this Schedule B and all Reimbursable Expenses shall comply with the D-1 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 provisions of Section 3.5.1 below. There shall be no overtime pay on Basic Services or Additional Services without OWNER'S prior written approval. B.2.5. The compensation provided for under Sections 2.1 of this Schedule B, shall be the total and complete amount payable to CONSULTANT for the Basic Services to be performed under the provisions of this Agreement, and shall include the cost of all materials, equipment, supplies and out-of-pocket expenses incurred in the performance of all such services. B.2.6 Notwithstanding anything in this Agreement to the contrary, CONSULTANT acknowledges and agrees that in the event of a dispute concerning payments for Services performed under this Agreement, CONSULTANT shall continue to perform the Services required of it under this Agreement, as directed by OWNER, pending resolution of the dispute provided that OWNER continues to pay to CONSULTANT all amounts that OWNER does not dispute are due and payable. 3. SCHEDULE OF PAYMENTS: B.3.1. CONSULTANT shall submit, with each of the monthly status reports provided for under Section 1.1 of this Schedule B, an invoice for fees earned in the performance of Basic Services and Additional Services during the subject billing month. Notwithstanding anything herein to the contrary, the CONSULTANT shall submit no more than one invoice per month for all fees and Reimbursable Expenses earned that month for both Basic Services and Additional Services. Invoices shall be reasonably substantiated, identify the services rendered and must be submitted in triplicate in a form and manner required by Owner. Additionally, the number of the purchase order granting approval for such services shall appear on all invoices. B.3.1.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and approval of invoices submitted on the date of services or within six (6) months after completion of contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of the essence with respect to the timely submission of invoices under this agreement. B.3.2. Invoices not properly prepared (mathematical errors, billing not reflecting actual work done, no signature, etc.) shall be returned to CONSULTANT for correction. Invoices shall be submitted on CONSULTANT'S letterhead and must include the Purchase Order Number and the Project name and shall not be submitted more than one time monthly. B.3.3 Notwithstanding anything herein to the contrary, in no event may CONSULTANT'S monthly billings, on a cumulative basis, exceed the sum determined by multiplying the applicable not to exceed task limits set forth in the table in Section 2.1 by the percentage Owner has determined CONSULTANT has completed such task as of that particular monthly billing. B.3.4 Payments for Additional Services of CONSULTANT as defined in Article 2 hereinabove and for reimbursable expenses will be made monthly upon presentation of a detailed invoice with supporting documentation. D-2 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A1 ? B.3.5 Unless specific rates have been established in Attachment 1, attached to this Schedule B, CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized by CONSULTANT for Additional Services, CONSULTANT shall be limited to a maximum markup of 5% on the fees and expenses associated with such subconsultants and subcontractors. B.3.5.1 Reimbursable Expenses associated with Additional Services must comply with section 112.061, Fla. Stat., or as set forth in the Agreement, be charged without mark-up by the CONSULTANT, and shall consist only of the following items: B.3.5.1.1. Cost for reproducing documents that exceed the number of documents described in this Agreement and postage and handling of Drawings and Specifications. B.3.5.1.2. Travel expenses reasonably and necessarily incurred with respect to Project related trips, to the extent such trips are approved by OWNER. Such expenses, if approved by OWNER, may include coach airfare, standard accommodations and meals, all in accordance with section 112.061, F.S. Further, such expenses, if approved by OWNER, may include mileage for trips that are from/to destinations outside of Collier or Lee Counties. Such trips within Collier and Lee Counties are expressly excluded. B.3.5.1.3. Permit Fees required by the Project. B.3.5.1.4 Expense of overtime work requiring higher than regular rates approved in advance and in writing by OWNER. B.3.5.1.5 Expense of models for the County's use. B.3.5.1.6 Other items on request and approved in writing by the OWNER. B.3.5.1.7 To the extent that the County requires the Consultant to maintain a field office as provided in Schedule A, Section 6.3 of the Contract, the allowable expense, subject to the County's approval of the field office, is limited to the actual cost of rent, without any mark-up. D-3 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16 A 17 Attachment 1 SCHEDULE B CONSULTANT'S AND SUBCONSULTANT(S) HOURLY RATE SCHEDULE Title Standard Hourly Rate Principal $195 Senior Project Manager $170 Project Manager $150 Senior Engineer $165 Engineer $129 Senior Inspector $95 Inspector $75 Clerical/Administrative Assistant $65 The above hourly rates are applicable to Time and Materials task(s) only. The above list may not be all inclusive. Additional hourly rates for other personnel may be added upon mutual agreement in advance and in writing by the Project Manager and the Consultant. Subconsultant fees are included in the Schedule B, Section B.2.1. Invoices for subconsultant services which have been provided on a Time and Materials basis shall include a reference to the appropriate phase at the time the invoice is submitted, along with the appropriate associated hourly rate. D-4 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. ob^ 1 6A 17 SCHEDULE C PROJECT MILESTONE SCHEDULE Cumulative Number of Calendar Days For Completion Items Description from Date of Notice to Proceed for Services under this Agreement A.1 Preconstruction Activities 30 days A.2 Construction Engineering and Inspection 540 days Activities A.3 Construction Engineering and Inspection 0 days Activates OT A.4 Post Construction Activities 30 days D-1 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 .6A1 ? SCHEDULE D INSURANCE COVERAGE (1) The amounts and types of insurance coverage shall conform to the following minimum requirements with the use of Insurance Services Office (ISO) forms and endorsements or their equivalents. If CONSULTANT has any self-insured retentions or deductibles under any of the below listed minimum required coverages, CONSULTANT must identify on the Certificate of Insurance the nature and amount of such self-insured retentions or deductibles and provide satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or deductibles will be CONSULTANT'S sole responsibility. (2) The insurance required by this Agreement shall be written for not less than the limits specified herein or required by law, whichever is greater. (3) Coverages shall be maintained without interruption from the date of commencement of the services until the date of completion and acceptance of the Project by the OWNER or as specified in this Agreement, whichever is longer. (4) Certificates of insurance (3 copies) acceptable to the OWNER shall be filed with the OWNER within ten (10) calendar days after Notice of Award is received by CONSULTANT evidencing the fact that CONSULTANT has acquired and put in place the insurance coverages and limits required hereunder. In addition, certified, true and exact copies of all insurance polices required shall be provided to OWNER, on a timely basis, if requested by OWNER. Such certificates shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least thirty (30) days prior written notice has been given to the OWNER. CONSULTANT shall also notify OWNER, in a like manner, within twenty-four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer, and nothing contained herein D-1 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 0 1 6 A 1 7 shall relieve CONSULTANT of this requirement to provide notice. In the event of a reduction in the aggregate limit of any policy to be provided by CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. (5) All insurance coverages of the CONSULTANT shall be primary to any insurance or self insurance program carried by the OWNER applicable to this Project. (6) The acceptance by OWNER of any Certificate of Insurance does not constitute approval or agreement by the OWNER that the insurance requirements have been satisfied or that the insurance policy shown on the Certificate of Insurance is in compliance with the requirements of this Agreement. (7) CONSULTANT shall require each of its subconsultants to procure and maintain, until the completion of the subconsultant's services, insurance of the types and to the limits specified in this Section except to the extent such insurance requirements for the subconsultant are expressly waived in writing by the OWNER. (8) Should at any time the CONSULTANT not maintain the insurance coverages required herein, the OWNER may terminate the Agreement or at its sole discretion shall be authorized to purchase such coverages and charge the CONSULTANT for such coverages purchased. If CONSULTANT fails to reimburse OWNER for such costs within thirty (30) days after demand, OWNER has the right to offset these costs from any amount due CONSULTANT under this Agreement or any other agreement between OWNER and CONSULTANT. The OWNER shall be under no obligation to purchase such insurance, nor shall it be responsible for the coverages purchased or the insurance company or companies used. The decision of the OWNER to purchase such insurance coverages shall in no way be construed to be a waiver of any of its rights under the Agreement. D-2 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 1 7 (9) If the initial, or any subsequently issued Certificate of Insurance expires prior to the completion of the services required hereunder or termination of the Agreement, the CONSULTANT shall furnish to the OWNER, in triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3) business days after the renewal of the policy(ies). Failure of the Contractor to provide the OWNER with such renewal certificate(s) shall be deemed a material breach by CONSULTANT and OWNER may terminate the Agreement for cause. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY Required by this Agreement? _X Yes No (1) Workers' Compensation and Employers' Liability Insurance shall be maintained by the CONSULTANT during the term of this Agreement for all employees engaged in the work under this Agreement in accordance with the laws of the State of Florida. The amounts of such insurance shall not be less than: a. Worker's Compensation - Florida Statutory Requirements b. Employers' Liability (check one, if applicable) $500,000 Each Accident _X $500,000 Disease Aggregate $500,000 Disease Each Employee $1,000,000 Each Accident $1,000,000 Disease Aggregate $1,000,000 Disease Each Employee (2) The insurance company shall waive all claims rights against the OWNER and the policy shall be so endorsed. D-3 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 1 6 A 1 7 (3) United States Longshoreman's and Harborworker's Act coverage shall be maintained where applicable to the completion of the work. Applicable _X_ Not Applicable (4) Maritime Coverage (Jones Act) shall be maintained where applicable to the completion of the work. Applicable _X Not Applicable COMMERCIAL GENERAL LIABILITY Required by this Agreement? X Yes No (1) Commercial General Liability Insurance, written on an "occurrence" basis, shall be maintained by the CONSULTANT. Coverage will include, but not be limited to, Bodily Injury, Property Damage, Personal Injury, Contractual Liability for this Agreement, Independent Contractors, Broad Form Property Damage including Completed Operations and Products and Completed Operations Coverage. Products and Completed Operations coverage shall be maintained for a period of not less than five (5) years following the completion and acceptance by the OWNER of the work under this Agreement. Limits of Liability shall not be less than the following: Single Limit per Occurrence $300,000 Products/Completed Operations Aggregate $300,000 Aggregate $300,000 Single Limit per Occurrence $500,000 Products/Completed Operations Aggregate $500,000 Aggregate $500,000 X_ Single Limit per Occurrence $1,000,000 Products/Completed Operations Aggregate $2,000,000 Aggregate $2,000,000 D-4 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 (2) The General Aggregate Limit shall apply separately to this Project and the policy shall be endorsed using the following endorsement wording. "This endorsement modifies insurance provided under the following: Commercial General Liability Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies separately to each of your projects away from premises owned by or rented to you." Applicable deductibles or self-insured retentions shall be the sole responsibility of CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT shall be subject to the approval of the Risk Management Director or his/her designee. (3) The OWNER, Collier County Government, shall be named as an Additional Insured and the policy shall be endorsed that such coverage shall be primary to any similar coverage carried by the OWNER. (4) Watercraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than the Commercial General Liability limit shown in subparagraph (1) above if applicable to the completion of the Services under this Agreement. Applicable _X Not Applicable (5) Aircraft Liability coverage shall be carried by the CONSULTANT or the SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable to the completion of the Services under this Agreement. Applicable _X Not Applicable AUTOMOBILE LIABILITY INSURANCE Required by this Agreement? X_Yes No D-5 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc !". 1 6 A 1 7 (1) Automobile Liability Insurance shall be maintained by the CONSULTANT for the ownership, maintenance or use of any owned, non-owned or hired vehicle with limits of not less than: Bodily Injury & Property Damage - $ 500,000 X_ Bodily Injury & Property Damage - $1,000,000 UMBRELLA LIABILITY (1) Umbrella Liability may be maintained as part of the liability insurance of the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability, Commercial General Liability, and Automobile Liability coverages required herein and shall include all coverages on a "following form" basis. (2) The policy shall contain wording to the effect that, in the event of the exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will "drop down" to apply as primary insurance. PROFESSIONAL LIABILITY INSURANCE Required by this Agreement? _X Yes No (1) Professional Liability Insurance shall be maintained by the CONSULTANT to insure its legal liability for claims arising out of the performance of professional services under this Agreement. CONSULTANT waives its right of recover against OWNER as to any claims under this insurance. Such insurance shall have limits of not less than: $ 500,000 each claim and in the aggregate X $1,000,000 each claim and in the aggregate D-6 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. 16A17 $2,000,000 each claim and in the aggregate $5,000,000 each claim and in the aggregate (2) Any deductible applicable to any claim shall be the sole responsibility of the CONSULTANT. Deductible amounts are subject to the approval of the OWNER. (3) The CONSULTANT shall continue this coverage for this Project for a period of not less than five (5) years following completion and acceptance of the Project by the OWNER. (4) The policy retroactive date will always be prior to the date services were first performed by CONSULTANT or OWNER, and the date will not be moved forward during the term of this Agreement and for five years thereafter. CONSULTANT shall promptly submit Certificates of Insurance providing for an unqualified written notice to OWNER of any cancellation of coverage or reduction in limits, other than the application of the aggregate limits provision. In addition, CONSULTANT shall also notify OWNER by certified mail, within twenty- four (24) hours after receipt, of any notices of expiration, cancellation, non-renewal or material change in coverages or limits received by CONSULTANT from its insurer. In the event of more than a twenty percent (20%) reduction in the aggregate limit of any policy, CONSULTANT shall immediately take steps to have the aggregate limit reinstated to the full extent permitted under such policy. CONSULTANT shall promptly submit a certified, true copy of the policy and any endorsements issued or to be issued on the policy if requested by OWNER. VALUABLE PAPERS INSURANCE (1) In the sole discretion of the County, CONSULTANT may be required to purchase valuable papers and records coverage for plans, specifications, drawings, reports, maps, books, blueprints, and other printed documents in an amount sufficient to cover the cost of recreating or reconstructing valuable papers or records utilized during the term of this Agreement. D-7 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc. o6, J 16A17 PROJECT PROFESSIONAL LIABILITY (1) If OWNER notifies CONSULTANT that a project professional liability policy will be purchased, then CONSULTANT agrees to use its best efforts in cooperation with OWNER and OWNER'S insurance representative, to pursue the maximum credit available from the professional liability carrier for a reduction in the premium of CONSULTANT'S professional liability policy. If no credit is available from CONSULTANT'S current professional policy underwriter, then CONSULTANT agrees to pursue the maximum credit available on the next renewal policy, if a renewal occurs during the term of the project policy (and on any subsequent professional liability policies that renew during the term of the project policy). CONSULTANT agrees that any such credit will fully accrue to OWNER. Should no credit accrue to OWNER, OWNER and CONSULTANT, agree to negotiate in good faith a credit on behalf of OWNER for the provision of project-specific professional liability insurance policy in consideration for a reduction in CONSULTANT'S self-insured retention and the risk of uninsured or underinsured consultants. (2) CONSULTANT agrees to provide the following information when requested by OWNER or OWNER'S Project Manager: a. The date the professional liability insurance renews. b. Current policy limits. c. Current deductibles/self-insured retention. d. Current underwriter. e. Amount (in both dollars and percent) the underwriter will give as a credit if the policy is replaced by an individual project policy. f. Cost of professional insurance as a percent of revenue. g. Affirmation that the design firm will complete a timely project errors and omissions application. (3) If OWNER elects to purchase a project professional liability policy, CONSULTANT to be insured will be notified and OWNER will provide professional liability insurance, naming CONSULTANT and its professional subconsultants as named insureds. END OF SCHEDULE D D-8 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc al 16A17 SCHEDULE E TRUTH IN NEGOTIATION CERTIFICATE In compliance with the Consultants' Competitive Negotiation Act, Section 287.055, Florida Statutes, AECOM Technical Services, Inc. hereby certifies that wages, rates and other factual unit costs supporting the compensation for the services of the CONSULTANT to be provided under the Professional Services Agreement, concerning CEI Services for Vanderbilt Drive Bridge Replacement Project, are accurate, complete and current as of the time of contracting. AECOM Technical Services, Ind l BY: V l V TITLE: v, t !E.- S'i0 t DATE: / ~43 /1/4 E-1 Agreement#15-6418"Vanderbilt Drive Bridge Replacement" AECOM Technical Services, Inc 1 6 A 17 SCHEDULE F KEY PERSONNEL, SUBCONSULTANTS AND SUBCONTRACTORS Name Personnel Category % of time Crystal Gorman Senior Project Manager 5% Steve Nappi Engineer 60% Julio Castro Senior Inspector 100% Joe Monahan Inspector 40% Michele Rastelli Clerical/Administrative 20% AECOM Survey Services 2%* FGE (Sub) Geotechnical Services 1%* Bolt Underwater (Sub) Underwater Inspection 0.5%* Ardaman (Sub) Materials Lab Testing 1%* *Utilized on an as needed basis in their respective areas of expertise. F-1 Agreement#15-6418"Vanderbilt Drive Bridge Replaceme AECOM Technical Services, I . . .. 16A17 DATE(MM/DD/YYYY) ACCORD CERTIFICATE OF LIABILITY INSURANCE ihm...,i- 1/1/2017 6/13/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Lockton Insurance Brokers,LLC CONTACT License#0F15767 PHONE FAX (A/C.No.Ext): (A/C,No): 4275 Executive Square,Suite 600 EMAIL La Jolla CA 92037 ADDRESS: (858)587-3100 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:*** SEE ATTACHMENT INSURED AECOM INSURER B: 1392522 AECOM Technical Services,Inc. INSURER C: 7650 W.Courtney Campbell Causeway INSURER D: Tampa FL 33607-1462 INSURER E: INSURER F: COVERAGES AECTE01 CERTIFICATE NUMBER: 14104131 REVISION NUMBER: XXXXXXX THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) LIMITS COMMERCIAL GENERAL LIABILITY NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX DAMAGE CLAIMS-MADE OCCUR PREM SESO(Ea occurrence) $ XXXXXXX MED EXP(Any one person) $ XXXXXXX PERSONAL&ADV INJURY $ XXXXXXX GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE _$ XXXXXXX POLICY PRC JECT LOC PRODUCTS-COMP/OP AGG $ XXXXXXX OTHER: $ AUTOMOBILE LIABILITY NOT APPLICABLE COMBINED SINGLE LIMIT $ (Ea accident) XXXXXXX ANY AUTO BODILY INJURY(Per person) $ XXXXXXX ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ XXXXXXX AUTOS AUTOS $ XXXXXXX NON-OWNED PROPERTY DAMAGE HIRED AUTOS _ AUTOS (Per accident) $ XXXXXXX UMBRELLA LIAB OCCUR NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX _ EXCESS LIAB CLAIMS-MADE AGGREGATE $ XXXXXXX DED RETENTION$ $ XXXXXXX A AND EMPLOYERS'LIABILITY WORKERS COMPENSATION Y/N N SEE ATTACHED ACORD 101 1/1/2016 1/1/2017 X PER E STATUTE ERH ANY PROPRIETOR/PARTNER/EXECUTIVEN/A E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Notice of Cancellation applies per attached endorsement.Re:Project No.OPP-380420,Contract No.15-6418.Provide CEI and Related Services for the replacement of two existing functionally obsolete bridges(#030177 and#030178),relocation of an existing pedestrian bridge,road resurfacing/reconstruction, utility relocation,intersection reconstruction and multi-use pathway construction on Vanderbilt Drive.Collier County Project Number:66066.11. CERTIFICATE HOLDER CANCELLATION See Attachments 14104131 Board of County Commissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier CountyFlorida THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Procurement Services Division 3327 Tamiami Trail East AUTHORIZED REPRESENTATIVE ^) - Naples FL 34112 -lam 1 „., t `l j'� �1 ©1014 ACORD CM- POFPa4410N. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16A 17 ACORD 101 Policy# Issuing Company State(s)Covered 0910710 National Union Fire Insurance Company of Pittsburgh,PA NAIC#19445 OH 014268016 The Insurance Company of the State of Pennsylvania-NAIC#19429 FL 014268017 The Insurance Company of the State of Pennsylvania-NAIC#19429 ME 014268019 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,KY 014268020 The Insurance Company of the State of Pennsylvania-NAIC#19429 NV 014268021 The Insurance Company of the State of Pennsylvania-NAIC#19429 CO 014268022 The Insurance Company of the State of Pennsylvania-NAIC#19429 NJ,PA 014268023 The Insurance Company of the State of Pennsylvania-NAIC#19429 MA,ND,OH,WA,WI,WY 014268024 The Insurance Company of the State of Pennsylvania-NAIC#19429 CA 014268025 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,KY,NC,NH,UT,VT 014268026 The Insurance Company of the State of Pennsylvania-NAIC#19429 AL,AR,CO,CT,DC,DE,GA,HI,IA,ID,IN,KS,LA,MD,MI,MN,MO,MS, MT,N E,NM,NV,NY,OK,OR,RI,SC,SD,TN,TX,W V 014268027 The Insurance Company of the State of Pennsylvania-NAIC#19429 AK,AZ,VA 014268028 The Insurance Company of the State of Pennsylvania-NAIC#19429 NY 014268018 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,WA 014268029 The Insurance Company of the State of Pennsylvania-NAIC#19429 CO,ID,NM,SC,TN 014268030 The Insurance Company of the State of Pennsylvania-NAIC#19429 TX Miscellaneous Attachment:M503712 Master ID: 1392522,Certificate ID: 14104131 16A17 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following "attaching clause" need be completed only when this endorsement is issued subsequent to preparation of the policy). This endorsement,effective 12:01 AM 1/1/2016 forms a part of Policy No.SEE ATTACHED ACORD 101 Issued to AECOM AECOM Technical Services, Inc. By The Insurance Company of the State of Pennsylvania LIMITED ADVICE OF CANCELLATION TO SCHEDULED ENTITIES (WORKERS' COMPENSATION ONLY) This policy is amended as follows: In the event that the Insurer cancels this policy for any reason other than non-payment of premium, and 1.the cancellation effective date is prior to this policy's expiration date; 2.the Named Insured or, if applicable, any other employers named in Item 1 of the Information Page is under an existing contractual obligation to notify a certificate holder(s)when this policy is canceled (hereinafter,the"Certificate Holder(s)")and the Named Insured has provided the Insurer, either directly or through its broker of record, either: (a)the name of the entity shown on the certificate,a contact name at such entity and the U.S. Postal Service mailing address of each such entity;or (b)the email address of a contact at each such entity; and 3. prior to the effective date of cancellation,the Named Insured confirms to the Insurer, either directly or through its broker of record,that the persons or organizations set forth in the Schedule below, as well as their respective addresses listed, should continue to be a part of the Schedule and, if not,the names of the persons or organizations that should be deleted, the Insurer will provide advice of cancellation(the"Advice")to each such Certificate Holder(s)confirmed by the Named Insured in writing to be correctly a part of the Schedule within 30 days after the Named Insured confirms the accuracy of the Schedule below with the Insurer; provided, however,that if a specific number of days is not stated above,then the Advice will be provided to such Certificate Holder(s)as soon as reasonably practicable after the Named Insured confirms the accuracy of the Schedule below with the Insurer. Proof of the Insurer emailing the Advice, using the information provided and subsequently confirmed by the Named Insured in writing,will serve as proof that the Insurer has fully satisfied its obligations under this endorsement. This endorsement does not affect, in any way, coverage provided under this policy or the cancellation of this policy or the effective date thereof, nor shall this endorsement invest any rights in any entity not insured under this policy. The following definitions apply to this endorsement: 1. Named Insured means the first named employer in Item 1 of the Information Page of this policy. 2. Insurer means the insurance company shown in the header on the Information Page of this policy. WC 99 00 58 (Ed.04/11) Attachment Code:D461827 Master ID: 1392522,Certificate ID: 14104131 ..., • 16A17 1 I ® DATE(MM/DDIYYYY) ACRD CERTIFICATE OF LIABILITY INSURANCE L..----'" 1/1/2017 6/13/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS 1 CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Lockton Insurance Brokers,LLC N°Aen ACT ',.. License#OF 15767 PHONE FAX (AIC.No.Ext): (A/C,No): 4275 Executive Square,Suite 600 E-MAIL La Jolla CA 92037 ADDRESS: (858)587-3100 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:*** SEE ATTACHMENT *** INSURED AECOM INSURER B: 1392522 AECOM Technical Services,Inc. INSURER C: 7650 W.Courtney Campbell Causeway INSURER D: Tampa FL 33607-1462 INSURER E: INSURER F: COVERAGES AECTE01 CERTIFICATE NUMBER: 14104131 REVISION NUMBER: XXXXXXX THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ISD WVD POLICY NUMBER (DDL SUBR MM/DD�YY) (MFF MIDD/YYYY) LIMITS COMMERCIAL GENERAL LIABILITY NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX DAMAGE TO RENTED CLAIMS-MADE OCCUR PREMISES(Ea occurrence) $ XXXXXXX MED EXP(Any one person) $ XXXXXXX _ PERSONAL&ADV INJURY $ XXXXXXX GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ XXXXXXX POLICY PRO- JECT LOC PRODUCTS-COMP/OP AGG $ XXXXXXX OTHER: $ AUTOMOBILE LIABILITY NOT APPLICABLE COMBINED SINGLE LIMIT $ (Ea accident) XXXXXXX ANY AUTO BODILY INJURY(Per person) $ XXXXXXX ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ XXXXXXX AUTOS AUTOS NON-OWNED PROPERTY DAMAGE $ XXXXXXX HIRED AUTOS AUTOS (Per accident) _ $ XXXXXXX UMBRELLA LIAB OCCUR NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX EXCESS LIAB CLAIMS-MADE AGGREGATE $ XXXXXXX DED RETENTION$ $ XXXXXXX 'WORKERS COMPENSATION PER OTH- A AND EMPLOYERS'LIABILITY Y/N N SEE ATTACHED ACORD 101 1/1/2016 1/1/2017 X STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Notice of Cancellation applies per attached endorsement.Re:Project No.OPP-380420,Contract No.15-6418.Provide CEI and Related Services for the replacement of two existing functionally obsolete bridges(#030177 and#030178),relocation of an existing pedestrian bridge,road resurfacing/reconstruction, utility relocation,intersection reconstruction and multi-use pathway construction on Vanderbilt Drive.Collier County Project Number:66066.11. CERTIFICATE HOLDER CANCELLATION See Attachments 14104131 Board of County Commissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier CountyFlorida THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Procurement Services Division 3327 Tamiami Trail East Naples FL 34112 AUTHORIZED REPRESENTATIVE '-:,..-----f---) „...4 ©188=2014 ACORD CIPOION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16A 17 ACORD 101 Policy# Issuing Company State(s)Covered 0910710 National Union Fire Insurance Company of Pittsburgh,PA-NAIC#19445 OH 014268016 The Insurance Company of the State of Pennsylvania-NAIC#19429 FL 014268017 The Insurance Company of the State of Pennsylvania-NAIC#19429 ME 014268019 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,KY 014268020 The Insurance Company of the State of Pennsylvania-NAIC#19429 NV 014268021 The Insurance Company of the State of Pennsylvania-NAIC#19429 CO 014268022 The Insurance Company of the State of Pennsylvania-NAIC#19429 NJ,PA 014268023 The Insurance Company of the State of Pennsylvania-NAIC#19429 MA,ND,OH,WA,WI,WY 014268024 The Insurance Company of the State of Pennsylvania-NAIC#19429 CA 014268025 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,KY,NC,NH,UT,VT 014268026 The Insurance Company of the State of Pennsylvania-NAIC#19429 AL,AR,CO,CT,DC,DE,GA,HI,IA,ID,IN,KS,LA,MD,MI,MN,MO,MS, MT,NE,NM,NV,NY,OK,OR,RI,SC,SD,TN,TX,WV 014268027 The Insurance Company of the State of Pennsylvania-NAIC#19429 AK,AZ,VA 014268028 The Insurance Company of the State of Pennsylvania-NAIC#19429, NY 014268018 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,WA 014268029 The Insurance Company of the State of Pennsylvania-NAIC#19429 CO,ID,NM,SC,TN 014268030 The Insurance Company of the State of Pennsylvania-NAIC#19429 TX Miscellaneous Attachment:M503712 Master ID: 1392522,Certificate ID: 14104131 16A17 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following "attaching clause" need be completed only when this endorsement is issued subsequent to preparation of the policy). This endorsement, effective 12:01 AM 1/1/2016 forms a part of Policy No. SEE ATTACHED ACORD 101 Issued to AECOM AECOM Technical Services, Inc. By The Insurance Company of the State of Pennsylvania LIMITED ADVICE OF CANCELLATION TO SCHEDULED ENTITIES (WORKERS' COMPENSATION ONLY) This policy is amended as follows: In the event that the Insurer cancels this policy for any reason other than non-payment of premium, and 1.the cancellation effective date is prior to this policy's expiration date; 2.the Named Insured or, if applicable, any other employers named in Item 1 of the Information Page is under an existing contractual obligation to notify a certificate holder(s)when this policy is canceled (hereinafter,the"Certificate Holder(s)")and the Named Insured has provided the Insurer,either directly or through its broker of record, either: (a)the name of the entity shown on the certificate,a contact name at such entity and the U.S. Postal Service mailing address of each such entity;or (b)the email address of a contact at each such entity; and 3. prior to the effective date of cancellation,the Named Insured confirms to the Insurer,either directly or through its broker of record,that the persons or organizations set forth in the Schedule below,as well as their respective addresses listed, should continue to be a part of the Schedule and, if not,the names of the persons or organizations that should be deleted, the Insurer will provide advice of cancellation (the"Advice")to each such Certificate Holder(s)confirmed by the Named Insured in writing to be correctly a part of the Schedule within 30 days after the Named Insured confirms the accuracy of the Schedule below with the Insurer; provided, however,that if a specific number of days is not stated above,then the Advice will be provided to such Certificate Holder(s)as soon as reasonably practicable after the Named Insured confirms the accuracy of the Schedule below with the Insurer. Proof of the Insurer emailing the Advice, using the information provided and subsequently confirmed by the Named Insured in writing,will serve as proof that the Insurer has fully satisfied its obligations under this endorsement. This endorsement does not affect, in any way,coverage provided under this policy or the cancellation of this policy or the effective date thereof, nor shall this endorsement invest any rights in any entity not insured under this policy. The following definitions apply to this endorsement: 1. Named Insured means the first named employer in Item 1 of the Information Page of this policy. 2. Insurer means the insurance company shown in the header on the Information Page of this policy. WC 99 00 58 (Ed.04/11) Attachment Code:D461827 Master ID: 1392522,Certificate ID: 14104131 , . 16A17 1 1 ACORD® CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) ‘...•-" 1/1/2017 6/13/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONT PRODUCER Lockton Insurance Brokers,LLC NAMEACT License#0F15767 PHONE FAX (A/C,No.Ext): (A/C,No): 4275 Executive Square,Suite 600 E-MAIL La Jolla CA 92037 ADDRESS: (858)587-3100 INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:*** SEE ATTACHMENT INSURED AECOM INSURER B: 1392522 AECOM Technical Services,Inc. INSURER C: 7650 W.Courtney Campbell Causeway INSURER D: Tampa FL 33607-1462 INSURER E: INSURER F: COVERAGES AECTE01 CERTIFICATE NUMBER: 14104131 REVISION NUMBER: XXXXXXX THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DDM'YY) LIMITS COMMERCIAL GENERAL LIABILITY NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX DAMAGE RENTE CLAIMS-MADE OCCUR PREM SESO(Ea occur ence) $ XXXXXXX MED EXP(Any one person) $ XXXXXXX PERSONAL&ADV INJURY $ XXXXXXX _ GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ XXXXXXX POLICY PRO- JECT LOC PRODUCTS-COMP/OP AGG $ XXXXXXX OTHER: $ AUTOMOBILE LIABILITY NOT APPLICABLE COMBINED SINGLE LIMIT $ (Ea accident) XXXXXXX - ANY AUTO BODILY INJURY(Per person) $ XXXXXXX ALL AUTOS OWNED _ SCHEDULED BODILY INJURY(Per accident) $ XXXXXXX _ NON-OWNED PROPERTY DAMAGE $ XXXXXXX HIRED AUTOS _ AUTOS (Per accident) $ XXXXXXX UMBRELLA LIAB _ OCCUR NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX EXCESS LIAB CLAIMS-MADE AGGREGATE $ XXXXXXX DED RETENTION$ $ XXXXXXX WORKERS COMPENSATIONPER OTH- N SEE ATTACHED ACORD 101 1/1/2016 1/1/2017 X STATUTE ER A AND EMPLOYERS'LIABILITY Y/N ANY PROPRIETOR/PARTNER/EXECUTIVEE.L. EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Notice of Cancellation applies per attached endorsement.Re:Project No.OPP-380420,Contract No. 15-6418.Provide CEI and Related Services for the replacement of two existing functionally obsolete bridges(#030177 and#030178),relocation of an existing pedestrian bridge,road resurfacing/reconstruction, utility relocation,intersection reconstruction and multi-use pathway construction on Vanderbilt Drive.Collier County Project Number:66066.11. CERTIFICATE HOLDER CANCELLATION See Attachments 14104131 Board of County Commissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier County Florida THE EXANCEION TH HDATE POLICY PROVIS OTHEREOF, TNSE WILL BE DELIVERED IN ACCProcurement Services Division 3327 Tamiami Trail East AUTHORIZED REPRESENTATIVE"' FL 34112 , --- �� r r ©198$8=2014 ACORD COf2POITION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16A17 ACORD 101 Policy# Issuing Company State(s)Covered 0910710 National Union Fire Insurance Company of Pittsburgh,PA-NAIC#19445 OH 014268016 The Insurance Company of the State of Pennsylvania-NAIC#19429 FL 014268017 The Insurance Company of the State of Pennsylvania-NAIC#19429 ME 014268019 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,KY 014268020 The Insurance Company of the State of Pennsylvania-NAIC#19429 NV 014268021 The Insurance Company of the State of Pennsylvania-NAIC#19429 CO 014268022 The Insurance Company of the State of Pennsylvania-NAIC#19429 NJ,PA 014268023 The Insurance Company of the State of Pennsylvania-NAIC#19429 MA,ND,OH,WA,WI,WY 014268024 The Insurance Company of the State of Pennsylvania-NAIC#19429 CA 014268025 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,KY,NC,NH,UT,VT 014268026 The Insurance Company of the State of Pennsylvania-NAIC#19429 AL,AR,CO,CT,DC,DE,GA,HI,IA,ID,IN,KS,LA,MD,MI,MN,MO,MS, MT,N E,N M,N V,NY,O K,O R,RI,S C,SD,TN,TX,W V 014268027 The Insurance Company of the State of Pennsylvania-NAIC#19429 AK,AZ,VA 014268028 The Insurance Company of the State of Pennsylvania-NAIC#19429 NY 014268018 The Insurance Company of the State of Pennsylvania-NAIC#19429 IL,WA 014268029 The Insurance Company of the State of Pennsylvania-NAIC#19429 CO,ID,NM,SC,TN 014268030 The Insurance Company of the State of Pennsylvania-NAIC#19429 TX Miscellaneous Attachment:M503712 Master ID: 1392522,Certificate ID: 14104131 1 6A 17 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following "attaching clause"need be completed only when this endorsement is issued subsequent to preparation of the policy). This endorsement, effective 12:01 AM 1/1/2016 forms a part of Policy No. SEE ATTACHED ACORD 101 Issued to AECOM AECOM Technical Services, Inc. By The Insurance Company of the State of Pennsylvania LIMITED ADVICE OF CANCELLATION TO SCHEDULED ENTITIES (WORKERS'COMPENSATION ONLY) This policy is amended as follows: In the event that the Insurer cancels this policy for any reason other than non-payment of premium, and 1.the cancellation effective date is prior to this policy's expiration date; 2.the Named Insured or, if applicable, any other employers named in Item 1 of the Information Page is under an existing contractual obligation to notify a certificate holder(s)when this policy is canceled (hereinafter,the"Certificate Holder(s)")and the Named Insured has provided the Insurer, either directly or through its broker of record, either: (a)the name of the entity shown on the certificate, a contact name at such entity and the U.S. Postal Service mailing address of each such entity; or (b)the email address of a contact at each such entity; and 3. prior to the effective date of cancellation,the Named Insured confirms to the Insurer, either directly or through its broker of record,that the persons or organizations set forth in the Schedule below, as well as their respective addresses listed, should continue to be a part of the Schedule and, if not,the names of the persons or organizations that should be deleted, the Insurer will provide advice of cancellation(the"Advice")to each such Certificate Holder(s)confirmed by the Named Insured in writing to be correctly a part of the Schedule within 30 days after the Named Insured confirms the accuracy of the Schedule below with the Insurer; provided, however,that if a specific number of days is not stated above,then the Advice will be provided to such Certificate Holder(s)as soon as reasonably practicable after the Named Insured confirms the accuracy of the Schedule below with the Insurer. Proof of the Insurer emailing the Advice, using the information provided and subsequently confirmed by the Named Insured in writing,will serve as proof that the Insurer has fully satisfied its obligations under this endorsement. This endorsement does not affect, in any way, coverage provided under this policy or the cancellation of this policy or the effective date thereof, nor shall this endorsement invest any rights in any entity not insured under this policy. The following definitions apply to this endorsement: 1. Named Insured means the first named employer in Item 1 of the Information Page of this policy. 2. Insurer means the insurance company shown in the header on the Information Page of this policy. WC 99 00 58 (Ed.04/11) Attachment Code:D461827 Master ID: 1392522,Certificate ID: 14104131 r � . . 1 6 A 1 7 ACCPRLf CERTIFICATE OF LIABILITY INSURANCE DATE 06/13/2016DmW) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Marsh Risk&Insurance Services NAMEPHONE: FAX CA License#0437153 (A/C.No,Ext): (AIC,No): 777 South Figueroa Street E-MAIL Los Angeles,CA 90017 ADDRESS: Attn:LosAngeles.CertRequest@Marsh.Com INSURER(S)AFFORDING COVERAGE NAIC# 06510-PROJ-GAUE-16-17 Tampa GLALP 06 2019 INSURER A:Zurich American Insurance Company 16535 INSURED INSURER B:N/A N/A AECOM AECOM Technical Services,Inc. INSURER C:Illinois Union Insurance Co 27960 7650 W.Courtney Campbell Causeway INSURER D Tampa,FL 33607-1462 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: LOS-002006064-01 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP WMILIMITS LTR INSD VD POLICY NUMBER (MDD/YYYY) (MMIDDIYYYY) A X COMMERCIAL GENERAL LIABILITY GLO 5965891 08 04/01/2016 04/01/2017 EACH OCCURRENCE _ $ 1,000,000 CLAIMS-MADE X OCCUR DAMAGE TO RENTED PREMISES(Ea occurrence) $ 1,000,000 MED EXP(Any one person) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY X JEC LOC _ PRODUCTS-COMP/OPAGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY BAP 5965893 08 04/01/2016 04/01/2017 COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS NON-OWNED PROPERTY DAMAGE HIRED AUTOS AUTOS (Per accident) UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ _$. WORKERS COMPENSATION PER OTH- ' AND EMPLOYERS'LIABILITY YIN STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? N I A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ C ARCHITECTS&ENG. EON G21654693 04/01/2016 04/01/2017 Per Claim/Agg $1,000,000 PROFESSIONAL LIAB. ""CLAIMS MADE"" Defense Included DESCRIPTION OF OPERATIONS 1 LOCATIONS 1 VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space Is required) Re:AECOM Project No:OPP-380420;Client Reference No:Contract No.15-6418;Provide CEI and Related Services for the replacement of two existing functionally obsolete bridges(#030177 and#030178),relocation of an existing pedestrian bridge,road resurfacing/reconstruction,utility relocation,intersection reconstruction and multi-use pathway construction on Vanderbilt Drive.Collier County Project Number:66066.11. (See Attached) CERTIFICATE HOLDER CANCELLATION Board of County Commissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier County Florida THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Procurement Services Division ACCORDANCE WITH THE POLICY PROVISIONS. 3327 Tamiami Trail East Naples,FL 34112 AUTHORIZED REPRESENTATIVE of Marsh Risk&Insurance Services James L.Vogel ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16A17 AGENCY CUSTOMER ID: 06510 LOC#: Los Angeles AC® ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY NAMED INSURED Marsh Risk&Insurance Services AECOM AECOM Technical Services,Inc. POLICY NUMBER 7650 W.Courtney Campbell Causeway , Tampa,FL 33607-1462 CARRIER NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Collier County Government is named as additional insured for GL coverage,but only as respects work performed by or on behalf of the named insured. This insurance is primary and non-contributory over any existing insurance and limited to liability arising out of the operations of the named insured and where required by written contract with respect to the GL coverage. Waiver of Subrogation is applicable where required by written contract with respect to GL and AL. Contractual Liability is included in the General Liability coverage. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD 1 6 A 1 7 ' 7 ® A DATE(MMIDDIYYYY)L7 CERTIFICATE OF LIABILITY INSURANCE 06/13/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Marsh Risk&Insurance Services NAMEPHONE: FAX CA License#0437153 (A/C,No,Ext): (A/C,No): 777 South Figueroa Street E-MAIL Los Angeles,CA 90017 ADDRESS: Attn:LosAngeles.CertRequest@Marsh.Com INSURER(S)AFFORDING COVERAGE NAIC# 06510-PROJ-GAUE-16-17 Tampa GLALP 06 2019 INSURER A:Zurich American Insurance Company 16535 INSURED INSURER B:N/A N/A AECOM AECOM Technical Services,Inc. INSURER c:Illinois Union Insurance Co 27960 7650 W.Courtney Campbell Causeway INSURER D: Tampa,FL 33607-1462 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: LOS-002006064-01 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR I POLICY EFF POLICY EXP LTR TYPE OF INSURANCE IN SD WVD POLICY NUMBER (MMIDD/YYYY) (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY GLO 5965891 08 04/01/2016 04/01/2017 EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR DAMAGE TO RENTEDPREMISES(Ea occurrence) $ 1,000,000 MED EXP(Any one person) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY X ECT LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY BAP 5965893 08 04/01/2016 04/01/2017 COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED - SCHEDULED BODILY INJURY(Per accident) $ AUTOS _ AUTOS NON-OWNED PROPERTY DAMAGE $ HIRED AUTOS AUTOS (Per accident) UMBRELLA LIAB _ OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? N I A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ C ARCHITECTS&ENG. EON G21654693 04/01/2016 04/01/2017 Per Claim/Agg $1,000,000 PROFESSIONAL LIAB. 'CLAIMS MADE- Defense Included DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Re:AECOM Project No:OPP-380420;Client Reference No:Contract No.15-6418;Provide CEI and Related Services for the replacement of two existing functionally obsolete bridges(#030177 and#030178),relocation of an existing pedestrian bridge,road resurfacing/reconstruction,utility relocation,intersection reconstruction and multi-use pathway construction on Vanderbilt Drive.Collier County Project Number:66066.11. (See Attached) CERTIFICATE HOLDER CANCELLATION Board of County Commissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier County Florida THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Procurement Services Division ACCORDANCE WITH THE POLICY PROVISIONS. 3327 Tamiami Trail East Naples,FL 34112 AUTHORIZED REPRESENTATIVE of Marsh Risk&Insurance Services James L.Vogel ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16A1 ? AGENCY CUSTOMER ID: 06510 LOC#: Los Angeles ACRD ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY NAMED INSURED Marsh Risk&Insurance Services AECOM AECOM Technical Services,Inc. POLICY NUMBER 7650 W.Courtney Campbell Causeway Tampa,FL 33607-1462 CARRIER NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Collier County Government is named as additional insured for GL coverage,but only as respects work performed by or on behalf of the named insured. This insurance is primary and non-contributory over any existing insurance and limited to liability arising out of the operations of the named insured and where required by written contract with respect to the GL coverage. Waiver of Subrogation is applicable where required by written contract with respect to GL and AL. Contractual Liability is included in the General Liability coverage. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD 1 6 A 1 7 A ATECCPREI CERTIFICATE OF LIABILITY INSURANCE D06/132016DmYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Marsh Risk&Insurance Services PHO PHONE: FAX CA License#0437153 (A/C,No,Ext): (A/C,No): 777 South Figueroa Street E-MAIL Los Angeles,CA 90017 ADDRESS: Attn:LosAngeles.CertRequest@Marsh.Com INSURER(S)AFFORDING COVERAGE NAIC# 06510-PROJ-GAUE-16-17 Tampa GLALP 06 2019 INSURER A:Zurich American Insurance Company 16535 INSURED INSURER B:N/A N/A AECOM AECOM Technical Services,Inc. INSURER c:Illinois Union Insurance Co 27960 7650 W.Courtney Campbell Causeway INSURER D: Tampa,FL 33607-1462 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: LOS-002006064-01 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADOL SUBR POLICY EFF POLICY EXP WLIMITS LTRINSD VD POLICY NUMBER (MMIDDIYYYY) (MMIDDIYYYY) A X COMMERCIAL GENERAL LIABILITY GLO 5965891 08 04/01/2016 04/01/2017 EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR DAMAGE TED PREMISES O(Ea occurrence)r $ 1,000,000 MED EXP(Any one person) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GE 'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY X Tai LOC PRODUCTS-COMP/OPAGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY BAP 5965893 08 04/01/2016 04/01/2017 COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS NON-OWNED PROPERTY DAMAGE HIRED AUTOS AUTOS (Per accident) UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY Y I N STATUTE ER ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? NIA — (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ C ARCHITECTS&ENG. EON G21654693 04/01/2016 04/01/2017 Per Claim/Agg $1,000,000 PROFESSIONAL LIAB. -CLAIMS MADE"" Defense Included DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Re:AECOM Project No:OPP-380420;Client Reference No:Contract No.15-6418;Provide CEI and Related Services for the replacement of two existing functionally obsolete bridges(#030177 and#030178),relocation of an existing pedestrian bridge,road resurfacing/reconstruction,utility relocation,intersection reconstruction and multi-use pathway construction on Vanderbilt Drive.Collier County Project Number:66066.11. (See Attached) CERTIFICATE HOLDER CANCELLATION Board of County Commissioners SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Collier County Florida THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Procurement Services Division ACCORDANCE WITH THE POLICY PROVISIONS. 3327 Tamiami Trail East Naples,FL 34112 AUTHORIZED REPRESENTATIVE of Marsh Risk&Insurance Services James L.Vogel ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD 16A17 AGENCY CUSTOMER ID: 06510 LOC#: Los Angeles _ ACC)RD ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY NAMED INSURED Marsh Risk&Insurance Services AECOM AECOM Technical Services,Inc. POLICY NUMBER 7650 W.Courtney Campbell Causeway Tampa,FL 33607-1462 CARRIER NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Collier County Government is named as additional insured for GL coverage,but only as respects work performed by or on behalf of the named insured. This insurance is primary and non-contributory over any existing insurance and limited to liability arising out of the operations of the named insured and where required by written contract with respect to the GL coverage. Waiver of Subrogation is applicable where required by written contract with respect to GL and AL. Contractual Liability is included in the General Liability coverage. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD 1 6 A 17 EV 7,\� usA ,,..,,,,,, II(IIII . ,-,,,,- ,,,,,,-2;i:..--- -!:.-- - ,,,,,„.<, Company ID Number: 19959 Client Company ID Number: 411650 THE E-VERIFY PROGRAM FOR EMPLOYMENT VERIFICATION MEMORANDUM OF UNDERSTANDING FOR EMPLOYERS USING A E-VERIFY EMPLOYER AGENT ARTICLE I PURPOSE AND AUTHORITY This Memorandum of Understanding (MOU) sets forth the points of agreement between the Department of Homeland Security (DHS), AECOM Technology Corporation (Employer), and TALX Corporation (E-Verify Employer Agent) regarding the Employer's and E-Verify Employer Agent's participation in the Employment Eligibility Verification Program (E-Verify). This MOU explains certain features of the E-Verify program and enumerates specific responsibilities of DHS, the Social Security Administration (SSA), the Employer, and the E-Verify Employer Agent. References to the Employer include the E-Verify Employer Agent when acting on behalf of the Employer. E-Verify is a program that electronically confirms an employee's eligibility to work in the United States after completion of the Employment Eligibility Verification Form (Form 1-9). For covered government contractors, E-Verify is used to verify the employment eligibility of all newly hired employees and all existing employees assigned to Federal contracts or to verify the entire workforce if the contractor so chooses. Authority for the E-Verify program is found in Title IV, Subtitle A, of the Illegal Immigration Reform and Immigrant Responsibility Act of 1996 (IIRIRA), Pub. L. 104-208, 110 Stat. 3009, as amended (8 U.S.C. § 1324a note). Authority for use of the E-Verify program by Federal contractors and subcontractors covered by the terms of Subpart 22.18, "Employment Eligibility Verification", of the Federal Acquisition Regulation (FAR) (hereinafter referred to in this MOU as a "Federal contractor with the FAR E-Verify clause") to verify the employment eligibility of certain employees working on Federal contracts is also found in Subpart 22.18 and in Executive Order 12989, as amended. ARTICLE II FUNCTIONS TO BE PERFORMED A. RESPONSIBILITIES OF SSA 1. SSA agrees to provide the Employer (through the E-Verify Employer Agent) with available information that will allow the Employer to confirm the accuracy of Social Security Numbers provided by all employees verified under this MOU and the employment authorization of U.S. citizens. 2. SSA agrees to provide the Employer and E-Verify Employer Agent appropriate assistance with operational problems that may arise during the Employer's participation in E-Verify. SSA agrees to provide the E-Verify Employer Agent with names, titles, addresses, and telephone numbers of SSA representatives to be contacted during the E-Verify Page 1 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.g ov/E-Verify 16A1 ? V 7 Company ID Number: 19959 Client Company ID Number: 411650 process. 3. SSA agrees to safeguard the information provided by the Employer through the E-Verify program procedures, and to limit access to such information, as is appropriate by law, to individuals responsible for the verification of Social Security Numbers and for evaluation of E-Verify or such other persons or entities who may be authorized by SSA as governed by the Privacy Act (5 U.S.C. § 552a), the Social Security Act (42 U.S.C. 1306(a)), and SSA regulations (20 CFR Part 401). 4. SSA agrees to provide a means of automated verification that is designed (in conjunction with DHS's automated system if necessary) to provide confirmation or tentative nonconfirmation of U.S. citizens' employment eligibility within 3 Federal Government work days of the initial inquiry. 5. SSA agrees to provide a means of secondary verification (including updating SSA records as may be necessary) for employees who contest SSA tentative nonconfirmations that is designed to provide final confirmation or nonconfirmation of U.S. citizens' employment eligibility and accuracy of SSA records for both citizens and non-citizens within 10 Federal Government work days of the date of referral to SSA, unless SSA determines that more than 10 days may be necessary. In such cases, SSA will provide additional verification instructions. B. RESPONSIBILITIES OF DHS 1. After SSA verifies the accuracy of SSA records for employees through E-Verify, DHS agrees to provide the Employer (through the E-Verify Employer Agent) access to selected data from DHS's database to enable the Employer (through the E-Verify Employer Agent) to conduct, to the extent authorized by this MOU: • Automated verification checks on employees by electronic means, and • Photo verification checks (when available) on employees. 2. DHS agrees to provide to the Employer and E-Verify Employer Agent appropriate assistance with operational problems that may arise during the Employer's participation in E-Verify. DHS agrees to provide the E-Verify Employer Agent names, titles, addresses, and telephone numbers of DHS representatives to be contacted during the E-Verify process. 3. DHS agrees to make available to the Employer (through the E-Verify Employer Agent), at the E-Verify Web site and on the E-Verify Web browser, instructional materials on E- Verify policies, procedures and requirements for both SSA and DHS, including restrictions on the use of E-Verify. OHS agrees to provide training materials on E-Verify. 4. DHS agrees to provide to the Employer(through the E-Verify Employer Agent) a notice, which indicates the Employer's participation in the E-Verify program. OHS also agrees to Page 2 of 15 E-Verify MOU for Employer(Client)using a E-Verify Employer Agent Revision Date 09/01/09 www.d hs.g ov/E-Verify 16A17 EVenly .:,,„ Company ID Number: 19959 Client Company ID Number: 411650 provide to the Employer(through the E-Verify Employer Agent) anti-discrimination notices issued by the Office of Special Counsel for Immigration-Related Unfair Employment Practices (OSC), Civil Rights Division, U.S. Department of Justice. 5. DHS agrees to issue the E-Verify Employer Agent a user identification number and password that will be used exclusively by the E-Verify Employer Agent, on behalf of the Employer, to verify information provided by employees with DHS's databases. 6. DHS agrees to safeguard the information provided to DHS by the Employer (through the E-Verify Employer Agent), and to limit access to such information to individuals responsible for the verification of employees' employment eligibility and for evaluation of the E-Verify program, or to such other persons or entities as may be authorized by applicable law. Information will be used only to verify the accuracy of Social Security Numbers and employment eligibility, to enforce the Immigration and Nationality Act (INA) and Federal criminal laws, and to administer Federal contracting requirements. 7. OHS agrees to provide a means of automated verification that is designed (in conjunction with SSA verification procedures) to provide confirmation or tentative nonconfirmation of employees' employment eligibility within 3 Federal Government workdays of the initial inquiry. 8. DHS agrees to provide a means of secondary verification (including updating OHS records as may be necessary) for employees who contest DHS tentative nonconfirmations and photo non-match tentative nonconfirmations that is designed to provide final confirmation or nonconfirmation of the employees' employment eligibility within 10 Federal Government work days of the date of referral to OHS, unless OHS determines that more than 10 days may be necessary. In such cases, DHS will provide additional verification instructions. C. RESPONSIBILITIES OF THE EMPLOYER 1. The Employer agrees to display the notices supplied by DHS (through the E-Verify Employer Agent) in a prominent place that is clearly visible to prospective employees and all employees who are to be verified through the system. 2. The Employer agrees to provide to the SSA and OHS the names, titles, addresses, and telephone numbers of the Employer representatives to be contacted regarding E-Verify. 3. The Employer agrees to become familiar with and comply with the most recent version of the E-Verify User Manual. The Employer will obtain the E-Verify User Manual from the E-Verify Employer Agent. 4. The Employer agrees to comply with current Form 1-9 procedures, with two exceptions: • If an employee presents a "List B” identity document, the Employer agrees to only accept "List B" documents that contain a photo. (List B documents identified in 8 Page 3 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.dhs.gov/E-Verify 1 6 A 1 7 Ey .401 - Company ID Number: 19959 Client Company ID Number: 411650 C.F.R. § 274a.2(b)(1)(B)) can be presented during the Form 1-9 process to establish identity.) If an employee objects to the photo requirement for religious reasons, the Employer should contact E-Verify at 1-888-464-4218. • If an employee presents a OHS Form 1-551 (Permanent Resident Card) or Form I- 766 (Employment Authorization Document) to complete the Form 1-9, the Employer agrees to make a photocopy of the document and to retain the photocopy with the employee's Form 1-9. The photocopy must be of sufficient quality to allow for verification of the photo and written information. The employer will use the photocopy to verify the photo and to assist OHS with its review of photo non-matches that are contested by employees. Note that employees retain the right to present any List A, or List B and List C, documentation to complete the Form 1-9. OHS may in the future designate other documents that activate the photo screening tool. 5. The Employer understands that participation in E-Verify does not exempt the Employer from the responsibility to complete, retain, and make available for inspection Forms 1-9 that relate to its employees, or from other requirements of applicable regulations or laws, including the obligation to comply with the antidiscrimination requirements of section 274B of the INA with respect to Form 1-9 procedures, except for the following modified requirements applicable by reason of the Employer's participation in E-Verify: (1) identity documents must have photos, as described in paragraph 4 above; (2) a rebuttable presumption is established that the Employer has not violated section 274A(a)(1)(A) of the Immigration and Nationality Act (INA) with respect to the hiring of any individual if it obtains confirmation of the identity and employment eligibility of the individual in good faith compliance with the terms and conditions of E-Verify; (3) the Employer must notify DHS if it continues to employ any employee after receiving a final nonconfirmation, and is subject to a civil money penalty between $550 and $1,100 for each failure to notify OHS of continued employment following a final nonconfirmation; (4) the Employer is subject to a rebuttable presumption that it has knowingly employed an unauthorized alien in violation of section 274A(a)(1)(A) if the Employer continues to employ an employee after receiving a final nonconfirmation; and (5) no person or entity participating in E-Verify is civilly or criminally liable under any law for any action taken in good faith based on information provided through the confirmation system. DHS reserves the right to conduct Form 1-9 and E-Verify system compliance inspections during the course of E- Verify, as well as to conduct any other enforcement activity authorized by law. 6. The Employer agrees to initiate E-Verify verification procedures (through the E-Verify Employer Agent), for new employees within 3 Employer business days after each employee has been hired (but after both sections 1 and 2 of the Form 1-9 have been completed), and to complete as many (but only as many) steps of the E-Verify process as are necessary according to the E-Verify User Manual, or in the case of Federal contractors with the FAR E-Verify clause, the E-Verify User Manual for Federal Contractors. The Employer is prohibited from initiating verification procedures before the employee has been hired and the Form 1-9 completed. If the automated system to be queried is temporarily unavailable, the 3-day time period is extended until it is again operational in order to accommodate the Employer's attempting, in good faith, to make Page 4 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent Revision Date 09/01/09 www.d h s.g ov/E-Verify 16A17 E ,,:,_ Amok ,,N. ,.,. M USA wri y , r n�i�l�il :., a Company ID Number: 19959 Client Company ID Number: 411650 inquiries during the period of unavailability. Employers may initiate verification, through the E-Verify Employer Agent, by notating the Form 1-9 in circumstances where the employee has applied for a Social Security Number (SSN) from the SSA and is waiting to receive the SSN, provided that the Employer (through the E-Verify Employer Agent) performs an E-Verify employment verification query using the employee's SSN as soon as the SSN becomes available. 7. The Employer agrees not to use E-Verify procedures for pre-employment screening of job applicants, in support of any unlawful employment practice, or for any other use not authorized by this MOU. Employers must use E-Verify (through its E-Verify Employer Agent) for all new employees, unless an Employer is a Federal contractor that qualifies for the exceptions described in Article II.D.1.c. Except as provided in Article II.D, the Employer will not verify selectively and will not verify employees hired before the effective date of this MOU. The Employer understands that if the Employer uses the E- Verify system for any purpose other than as authorized by this MOU, the Employer may be subject to appropriate legal action and termination of its access to SSA and DHS information pursuant to this MOU. 8. The Employer (through its E-Verify Employer Agent) agrees to follow appropriate procedures (see Article III. below) regarding tentative nonconfirmations, including I notifying employees in private of the finding and providing them written notice of the findings, providing written referral instructions to employees, allowing employees to contest the finding, and not taking adverse action against employees if they choose to contest the finding. Further, when employees contest a tentative nonconfirmation based upon a photo non-match, the Employer is required to take affirmative steps (see Article III.B. below) to contact DHS with information necessary to resolve the challenge. 9. The Employer agrees not to take any adverse action against an employee based upon the employee's perceived employment eligibility status while SSA or OHS is processing the verification request unless the Employer obtains knowledge (as defined in 8 C.F.R. § 274a.1(I)) that the employee is not work authorized. The Employer understands that an initial inability of the SSA or OHS automated verification system to verify work authorization, a tentative nonconfirmation, a case in continuance (indicating the need for additional time for the government to resolve a case), or the finding of a photo non- match, does not establish, and should not be interpreted as evidence, that the employee is not work authorized. In any of the cases listed above, the employee must be provided a full and fair opportunity to contest the finding, and if he or she does so, the employee may not be terminated or suffer any adverse employment consequences based upon the employee's perceived employment eligibility status (including denying, reducing, or extending work hours, delaying or preventing training, requiring an employee to work in poorer conditions, refusing to assign the employee to a Federal contract or other assignment, or otherwise subjecting an employee to any assumption that he or she is unauthorized to work, or otherwise mistreating an employee) until and unless secondary verification by SSA or DHS has been completed and a final nonconfirmation has been issued. If the employee does not choose to contest a tentative nonconfirmation or a Page 5 of 15 I E-Venfy MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.dhs.gov/E-Verify 1 6 A 1 7 p- -VeriFy Company ID Number: 19959 Client Company ID Number: 411650 photo non-match or if a secondary verification is completed and a final nonconfirmation is issued, then the Employer can find the employee is not work authorized and terminate the employee's employment. Employers or employees with questions about a final nonconfirmation may call E-Verify at 1-888-464-4218 or OSC at 1-800-255-8155 or 1- 800-237-2515 (TDD). 10. The Employer agrees to comply with Title VII of the Civil Rights Act of 1964 and section 274B of the INA, as applicable, by not discriminating unlawfully against any individual in hiring, firing, or recruitment or referral practices because of his or her national origin or, in the case of a protected individual as defined in section 274B(a)(3) of the INA, because of his or her citizenship status. The Employer understands that such illegal practices can include selective verification or use of E-Verify except as provided in part D below, or discharging or refusing to hire employees because they appear or sound "foreign" or have received tentative nonconfirmations. The Employer further understands that any violation of the unfair immigration-related employment practices provisions in section 274B of the INA could subject the Employer to civil penalties, back pay awards, and other sanctions, and violations of Title VII could subject the Employer to back pay awards, compensatory and punitive damages. Violations of either section 274B of the INA or Title VII may also lead to the termination of its participation in E-Verify. If the Employer has any questions relating to the anti-discrimination provision, it should contact OSC at 1-800-255-8155 or 1-800-237-2515 (TDD). 11. The Employer agrees to record the case verification number on the employee's Form 1-9 or to print the screen containing the case verification number and attach it to the employee's Form 1-9. 12. The Employer agrees that it will use the information it receives from SSA or DHS (through the E-Verify Employer Agent) pursuant to E-Verify and this MOU only to confirm the employment eligibility of employees as authorized by this MOU. The Employer agrees that it will safeguard this information, and means of access to it (such as PINS and passwords) to ensure that it is not used for any other purpose and as necessary to protect its confidentiality, including ensuring that it is not disseminated to any person other than employees of the Employer who are authorized to perform the Employer's responsibilities under this MOU, except for such dissemination as may be authorized in advance by SSA or OHS for legitimate purposes. 13. The Employer acknowledges that the information which it receives through the E-Verify Employer Agent from SSA is governed by the Privacy Act (5 U.S.C. § 552a(i)(1) and (3)) and the Social Security Act (42 U.S.C. 1306(a)), and that any person who obtains this information under false pretenses or uses it for any purpose other than as provided for in this MOU may be subject to criminal penalties. 14. The Employer agrees to cooperate with DHS and SSA in their compliance monitoring and evaluation of E-Verify, including by permitting OHS and SSA, upon reasonable notice, to review Forms 1-9 and other employment records and to interview it and its Page 6 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.gov/E-Verify . ., . 1 6 A 1 7 E-VeriFyYa�c x,S5„x..,. Company ID Number: 19959 Client Company ID Number: 411650 employees regarding the Employer's use of E-Verify, and to respond in a timely and accurate manner to DHS requests for information relating to their participation in E- Verify. D. RESPONSIBILITIES OF FEDERAL CONTRACTORS WITH THE FAR E-VERIFY CLAUSE 1. The Employer understands that if it is a Federal contractor subject to the employment verification terms in Subpart 22.18 of the FAR it must verify the employment eligibility of any existing employee assigned to the contract and all new hires, as discussed in the Supplemental Guide for Federal Contractors. Once an employee has been verified through E-Verify by the Employer, the Employer may not reverify the employee through E-Verify. a. Federal contractors with the FAR E-Verify clause agree to become familiar with and comply with the most recent versions of the E-Verify User Manual for Federal Contractors and the E-Verify Supplemental Guide for Federal Contractors. b. Federal contractors with the FAR E-Verify clause agree to complete a tutorial for Federal contractors with the FAR E-Verify clause. c. Federal contractors with the FAR E-Verify clause not enrolled at the time of contract award: An Employer that is not enrolled in E-Verify as a Federal contractor at the time of a contract award must enroll as a Federal contractor with the FAR E-Verify clause in E-Verify within 30 calendar days of contract award and, within 90 days of enrollment, begin to use E-Verify to initiate verification of employment eligibility of new hires of the Employer who are working in the United States, whether or not assigned to the contract. Once the Employer begins verifying new hires, such verification of new hires must be initiated within 3 business days after the date of hire. Once enrolled in E-Verify as a Federal contractor with the FAR E-Verify clause, the Employer must initiate verification of employees assigned to the contract within 90 calendar days from the time of enrollment in the system and then selecting which employees will be verified in E-Verify or within 30 days of an employee's assignment to the contract, whichever date is later. d. Employer that are already enrolled in E-Verify at the time of a contract award but are not enrolled in the system as a Federal contractor with the FAR E-Verify clause: Employers enrolled in E-Verify as a Federal contractor for 90 days or more at the time of a contract award must use E-Verify to initiate verification of employment eligibility for new hires of the Employer who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire. Employers enrolled in E-Verify as other than a Federal contractor with the FAR E-Verify clause, must update E-Verify to indicate that they are a Federal contractor with the FAR E-Verify clause within 30 days after Page 7 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.g ov/E-Verify 16A17 MI - en E ,,,,o, 4.1:"..1 '''' Company ID Number: 19959 Client Company ID Number: 411650 assignment to the contract. If the Employer is enrolled in E-Verify for 90 calendar days or less at the time of contract award, the Employer must, within 90 days of enrollment, begin to use E-Verify to initiate verification of new hires of the contractor who are working in the United States, whether or not assigned to the contract. Such verification of new hires must be initiated within 3 business days after the date of hire. An Employer enrolled as a Federal contractor with the FAR E-Verify clause in E-Verify must initiate verification of each employee assigned to the contract within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever is later. e. Institutions of higher education, State, local and tribal governments and sureties: Federal contractors with the FAR E-Verify clause that are institutions of higher education (as defined at 20 U.S.C. 1001(a)), State or local governments, governments of Federally recognized Indian tribes, or sureties performing under a takeover agreement entered into with a Federal agency pursuant to a performance bond may choose to only verify new and existing employees assigned to the Federal contract. Such Federal contractors with the FAR E- Verify clause may, however, elect to verify all new hires, and/or all existing employees hired after November 6, 1986. The provisions of Article II, part D, paragraphs 1.a and 1.b of this MOU providing timeframes for initiating employment verification of employees assigned to a contract apply to such institutions of higher education, State, local , tribal governments, and sureties. f. Verification of all employees: Upon enrollment, Employers who are Federal contractors with the FAR E-Verify clause may elect to verify employment eligibility of all existing employees working in the United States who were hired after November 6, 1986, instead of verifying only new employees and those existing employees assigned to a covered Federal contract. After enrollment, Employers must elect to do so only in the manner designated by DHS and initiate E-Verify verification of all existing employees within 180 days after the election. g. Form 1-9 procedures for existing employees of Federal contractors with the FAR E-Verify clause: Federal contractors with the FAR E-Verify clause (through their E-Verify Employer Agent) may choose to complete new Forms 1-9 for all existing employees other than those that are completely exempt from this process. Federal contractors with the FAR E-Verify clause may also update previously completed Forms 1-9 to initiate E-Verify verification of existing employees who are not completely exempt as long as that Form 1-9 is complete (including the SSN), complies with Article II.C.4, the employee's work authorization has not expired, and the Employer has reviewed the information reflected in the Form 1-9 either in person or in communications with the employee to ensure that the employee's stated basis in section 1 of the Form 1-9 for work authorization has not changed (including, but not limited to, a lawful permanent resident alien having become a naturalized U.S. citizen). If the Employer is unable to determine that the Form 1-9 complies with Article II.C.4, if the employee's basis Page 8 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.g ov/E-Verify , .. 16A17 E-VeriFy .,,, . , „„,„ ,4,„.,,,,, „.„,„,::, , • , .,...„,,, Company ID Number: 19959 Client Company ID Number: 411650 for work authorization as attested in section 1 has expired or changed, or if the Form 1-9 contains no SSN or is otherwise incomplete, the Employer shall complete a new 1-9 consistent with Article 11.0.4, or update the previous 1-9 to provide the necessary information. If section 1 of the Form 1-9 is otherwise valid and up-to-date and the form otherwise complies with Article 11.0.4, but reflects documentation (such as a U.S. passport or Form 1-551) that expired subsequent to completion of the Form 1-9, the Employer shall not require the production of additional documentation, or use the photo screening tool described in Article 11.0.4, subject to any additional or superseding instructions that may be provided on this subject in the Supplemental Guide for Federal Contractors. Nothing in this section shall be construed to require a second verification using E-Verify of any assigned employee who has previously been verified as a newly hired employee under this MOU, or to authorize verification of any existing employee by any Employer that is not a Federal contractor with the FAR E-Verify clause. 2. The Employer understands that if it is a Federal contractor with the FAR E-Verify clause, its compliance with this MOU is a performance requirement under the terms of the Federal contract or subcontract, and the Employer consents to the release of information relating to compliance with its verification responsibilities under this MOU to contracting officers or other officials authorized to review the Employer's compliance with Federal contracting requirements. E. RESPONSIBILITIES OF THE E-VERIFY EMPLOYER AGENT 1. The E-Verify Employer Agent agrees to provide to the SSA and DHS the names, titles, addresses, and telephone numbers of the E-Verify Employer Agent representatives who will be accessing information under E-Verify. 2. The E-Verify Employer Agent agrees to become familiar with and comply with the E- Verify User Manual and provide a copy of the manual to the Employer so that the Employer can become familiar with and comply with E-Verify policy and procedures. 3. The E-Verify Employer Agent agrees that any E-Verify Employer Agent Representative who will perform employment verification queries will complete the E-Verify Tutorial before that individual initiates any queries. a. The E-Verify Employer Agent agrees that all E-Verify Employer Agent representatives will take the refresher tutorials initiated by the E-Verify program as a condition of continued use of E-Verify, including any tutorials for Federal contractors if the Employer is a Federal contractor. b. Failure to complete a refresher tutorial will prevent the E-Verify Employer Agent and Employer from continued use of the program. 4. The E-Verify Employer Agent agrees to obtain the necessary equipment to utilize E- Verify. Page 9 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.g ov/E-Verify . . . 16A1 ? E-VeriIy „, � �f =x -,. , Company ID Number: 19959 Client Company ID Number: 411650 5. The E-Verify Employer Agent agrees to provide the Employer with the notices described in Article 11.6.4 above. 6. The E-Verify Employer Agent agrees to initiate E-Verify procedures on behalf of the Employer in accordance with the E-Verify Manual and E-Verify Web-Based Tutorial. The E-Verify Employer Agent will query the automated system using information provided by the Employer and will immediately communicate the response back to the Employer. If the automated system to be queried is temporarily unavailable, the 3-day time period is extended until it is again operational in order to accommodate the E-Verify Employer Agent's attempting, in good faith, to make inquiries on behalf of the Employer during the period of unavailability. In all cases, the E-Verify Employer Agent will use the SSA verification procedures first, and will use DHS verification procedures only as directed by the SSA verification response. 7. The E-Verify Employer Agent agrees to cooperate with DHS and SSA in their compliance monitoring and evaluation of E-Verify, including by permitting DHS and SSA, upon reasonable notice, to review Forms 1-9 and other employment records and to interview it and its employees regarding the use of E-Verify, and to respond in a timely and accurate manner to DHS requests for information relating to their participation in E- Verify. ARTICLE III REFERRAL OF INDIVIDUALS TO SSA AND DHS A. REFERRAL TO SSA 1. If the Employer receives a tentative nonconfirmation issued by SSA, the Employer must print the tentative nonconfirmation notice as directed by the automated system and provide it to the employee so that the employee may determine whether he or she will contest the tentative nonconfirmation. 2. The Employer will refer employees to SSA field offices only as directed by the automated system based on a tentative nonconfirmation, and only after the Employer records the case verification number, reviews the input to detect any transaction errors, and determines that the employee contests the tentative nonconfirmation. The Employer (through the E-Verify Employer Agent), will transmit the Social Security Number to SSA for verification again if this review indicates a need to do so. The Employer will determine whether the employee contests the tentative nonconfirmation as soon as possible after the Employer receives it. 3. If the employee contests an SSA tentative nonconfirmation, the Employer will provide the employee with a system-generated referral letter and instruct the employee to visit an SSA office within 8 Federal Government work days. SSA will electronically transmit the result of the referral to the Employer(through the E-Verify Employer Agent) within 10 Federal Government work days of the referral unless it determines that more than 10 Page 10 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.gov/E-Verify 16A17 Company ID Number: 19959 Client Company ID Number: 411650 days is necessary. The Employer agrees to check the E-Verify system regularly for case updates. 4. The Employer agrees not to ask the employee to obtain a printout from the Social Security Number database (the Numident) or other written verification of the Social Security Number from the SSA. B. REFERRAL TO DHS 1. If the Employer receives a tentative nonconfirmation issued by DHS, the Employer must print the tentative nonconfirmation notice as directed by the automated system and provide it to the employee so that the employee may determine whether he or she will contest the tentative nonconfirmation. 2. If the Employer finds a photo non-match for an employee who provides a document for which the automated system has transmitted a photo, the employer must print the photo non-match tentative nonconfirmation notice as directed by the automated system and provide it to the employee so that the employee may determine whether he or she will contest the finding. 3. The Employer agrees to refer individuals to DHS only when the employee chooses to contest a tentative nonconfirmation received from DHS automated verification process or when the Employer issues a tentative nonconfirmation based upon a photo non-match. The Employer will determine whether the employee contests the tentative nonconfirmation as soon as possible after the Employer receives it. 4. If the employee contests a tentative nonconfirmation issued by DHS, the Employer will provide the employee with a referral letter and instruct the employee to contact OHS through its toll-free hotline (as found on the referral letter) within 8 Federal Government work days. 5. If the employee contests a tentative nonconfirmation based upon a photo non-match, the Employer will provide the employee with a referral letter to OHS. DHS will electronically transmit the result of the referral to the Employer within 10 Federal Government work days of the referral unless it determines that more than 10 days is necessary. The Employer agrees to check the E-Verify system regularly for case updates. 6. The Employer agrees that if an employee contests a tentative nonconfirmation based upon a photo non-match, the Employer (or the E-Verify Employer Agent) will send a copy of the employee's Form 1-551 or Form 1-766 to DHS for review by: • Scanning and uploading the document, or • Sending a photocopy of the document by and express mail account (pain for at employer expense). 7. If the Employer (through the E-Verify Employer Agent) determines that there is a photo Page 11 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.g ov/E-Verify 16A17 „E e y Company ID Number: 19959 Client Company ID Number: 411650 non-match when comparing the photocopied List B document described in Article II.C.4 with the image generated in E-Verify, the Employer (through the E-Verify Employer Agent) must forward the employee's documentation to DHS using one of the means described in the preceding paragraph, and allow DHS to resolve the case. ARTICLE IV SERVICE PROVISIONS The SSA and DHS will not charge the Employer or the E-Verify Employer Agent for verification services performed under this MOU. OHS is not responsible for providing the equipment needed to make inquiries. A personal computer with Internet access is needed to access the E-Verify System. ARTICLE V PARTIES A. This MOU is effective upon the signature of all parties, and shall continue in effect for as long as the SSA and OHS conduct the E-Verify program unless modified in writing by the mutual consent of all parties, or terminated by any party upon 30 days prior written notice to the others. Any and all system enhancements to the E-Verify program by OHS or SSA, including but not limited to the E-Verify checking against additional data sources and instituting new verification procedures, will be covered under this MOU and will not cause the need for a supplemental MOU that outlines these changes. DHS agrees to train employers on all changes made to E-Verify through the use of mandatory refresher tutorials and updates to the E-Verify User Manual, the E-Verify User Manual for Federal Contractors, or the E-Verify Supplemental Guide for Federal Contractors. Even without changes to E- Verify, DHS reserves the right to require employers to take mandatory refresher tutorials. An Employer that is a Federal contractor with the FAR E-Verify clause may terminate this MOU when the Federal contract that requires its participation in E-Verify is terminated or completed. In such a circumstance, the Federal contractor with the FAR E-Verify clause must provide written notice to DHS. If an Employer that is a Federal contractor with the FAR E-Verify clause fails to provide such notice, that Employer will remain a participant in the E- Verify program, will remain bound by the terms of this MOU that apply to participants that are not Federal contractors with the FAR E-Verify clause, and will be required to use the E- Verify procedures to verify the employment eligibility of all newly hired employees. B. Notwithstanding Article V, part A of this MOU, OHS may terminate access to E-Verify if it is deemed necessary because of the requirements of law or policy, or upon a determination by SSA or OHS that there has been a breach of system integrity or security by the E-Verify Employer Agent or the Employer, or a failure on the part of either to comply with established procedures or legal requirements. The Employer understands that if it is a Federal contractor with the FAR E-Verify clause, termination of this MOU by any party for any reason may negatively affect the Employer's performance of its contractual responsibilities. Page 12 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d h s.g ov/E-Verify 4,,„, 16A17 ,_„:,,, EVenlyif ., n Company ID Number: 19959 Client Company ID Number: 411650 C. Some or all SSA and DHS responsibilities under this MOU may be performed by contractor(s), and SSA and DHS may adjust verification responsibilities between each other as they may determine necessary. By separate agreement with DHS, SSA has agreed to perform its responsibilities as described in this MOU. D. Nothing in this MOU is intended, or should be construed, to create any right or benefit, substantive or procedural, enforceable at law by any third party against the United States, its agencies, officers, or employees, or against the E-Verify Employer Agent, the Employer, or their agents, officers, or employees. E. Each party shall be solely responsible for defending any claim or action against it arising out of or related to E-Verify or this MOU, whether civil or criminal, and for any liability wherefrom, including (but not limited to) any dispute between the E-Verify Employer Agent or the Employer and any other person or entity regarding the applicability of Section 403(d) of IIRIRA to any action taken or allegedly taken by the E-Verify Employer Agent or the Employer. F. Participation in E-Verify is not confidential information and may be disclosed as authorized or required by law and DHS or SSA policy, including but not limited to, Congressional oversight, E-Verify publicity and media inquiries, determinations of compliance with Federal contractual requirements, and responses to inquiries under the Freedom of Information Act (FOIA). G. The foregoing constitutes the full agreement on this subject between DHS, the Employer and the E-Verify Employer Agent. AECOM Technology Corporation (Employer) hereby designates and appoints TALX Corporation (E-Verify Employer Agent), including its officers and employees, as the E-Verify Employer Agent for the purpose of carrying out AECOM Technology Corporation (Employer) responsibilities under the MOU between the Employer, the E-Verify Employer Agent, and OHS. Page 13 of 151 E-Verify MOU for Employer(Client)using a E-Verify Employer Agent 1 Revision Date 09/01/09 www.d h s.g ov/E-Verify 16A17 Everify Company ID Number: 19959 Client Company ID Number: 411650 The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer, the E-Verify Employer Agent and DHS respectively. If you have any questions, contact E-Verify at 1-888-464-4218. Approved by: Employer AECOM Technology Corporation rrra f r Title ▪€ata€tarn E-Verify Employer Agent TALX Corporation Jerald Jackson Name rr TNIe Electronically Signed 04/28/2011 S ignature. Date Department of Homeland Security—Verification Division USC1S VerificationDivision Name( ;easc T,pa$_ Electronically Signed :a06129/2011 iiaraatta ra Date Information Required For the E-Verify E-Verify Employer Agent Program Information relating to your Company: Page 14 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.dhs.gov/E-Verify 1 6-A 17 E-VerifyMsTO Company ID Number: 19959 Client Company ID Number: 411650 The individuals whose signatures appear below represent that they are authorized to enter into this MOU on behalf of the Employer, the E-Verify Employer Agent and DHS respectively. If you have any questions, contact E-Verify at 1-888-464-4218. Approved by: Employer AECOM Technology Corporation A1,, r k f IrQr c-,O �Lfr- -ZSU uree31 Name(Please Type or Print) . .Title !/ *OD/( AA Ai ASO Sig •':re Date E-Verify Employer Agent TALX Corporation Jerald Jackson Name(Please Type or Print) Title Electronically Signed 04/28/2011 Signature Date Department of Homeland Security—Verification Division Name(Please Type or Print) Title Signature Date Information Required For the E Verify E-Verify Employer Agent Program Information relating to your Company: Page 14 of 15 I E Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09!01109 www.dhs.gov/E-Verify 16A17 _. rVe al y aT,.. Company ID Number: 19959 Client Company ID Number: 411650 ....vr... Company NameAECOM Technology Corporation Company Facility Address:615 S. FLOWER ST. 3rd Fir Los Angeles,CA 90071-22a'- County oun or Parish:LOS ANGELES Employer Identification r: b r:6110886x:2 North American Industry Classification Systems Code:236 Administrator: Number of Employees: 16,00 r.: . Page 15 of 15 I E-Verify MOU for Employer(Client)using a E-Verify Employer Agent I Revision Date 09/01/09 www.d hs.g ov/E-Verify . . 16A17 a ,a. '. �n 4 :i -'E E-Verifr 1 „s.„ el ., w..... s Ie Las:.: Employment Eligibility Verification Joseph Johns .tJosctaw3 12 i PM-o21.04170is Log Out O, Herne Company Information My Cass. inc.: Ccip Client Company Name: AECOM k.$Edi '_ae i.f Fates. Client ID Number: 411650 My CScnts Doing Business As(DBA) Add New Client Name: View Existing clients DNS Number: 153561212 My Praree Edit Prefile; Physical Location: Mailing Address: Cage Password Address 1: 515 S.FLOWER ST. Address 1. Cnange Security Questions '. Address 2: 3rd Fir Address 2: My CO¢npairy City: Los Angeles City: Edit Company Profile state: CA State: Add New User Zip Code: S0071-2201 Zip Code: View Existing Users County: LOS ANGELES C: se Company Account My Reports Additional Information: View Reports Employer Identification Number:$110E8522 My Web Srvrvlces Total Number of Employees: 10,000 and over manage Wet Services Parent Orgaruza€ion: My Resources Administrator View Essential Resources. Take Tutorial ! Organization Designation: View User Mafiosi '.. Client Company Category:o Federal Contractor with FAR E Ateri\t Clause Snare Ideas Federal Contractor Category: None of these categones apply Contact Us Employees being van-died: Ali new trines and aft existing employees assigned to a Federal contract NAICS Code: 2336-CONSTRUCTION OF BUILDINGS `- ',7.i„,,,' 16A17 AECOM 213.593.8000 tel 1999 Avenue of the Stars 213.593.8730 fax Suite 2600 ICOM Los Angeles,CA 90067 www.aecom.com ASSISTANT SECRETARY'S CERTIFICATE AECOM a Delaware corporation I, Preston Hopson, DO HEREBY CERTIFY that I am the duly elected and acting Assistant Secretary of AECOM, a corporation organized under the laws of the State of Delaware(the"Corporation"), and the keeper of its records and corporate seal. I FURTHER CERTIFY that the Corporation's full legal address is c/o The Corporation Trust Company, 1209 Orange Street, Wilmington, Delaware 19801-0000 and that the Corporation's principal place of business is 1999 Avenue of the Stars, Suite 2600, Los Angeles, California 90067-6033. I FURTHER CERTIFY that The Earth Technology Corporation(USA), a corporation organized under the laws of the State of Delaware ("TETC (USA)"), is a direct wholly- owned subsidiary of the Corporation. I FURTHER CERTIFY that AECOM Technical Services, Inc., a corporation organized under the laws of California, is a direct wholly-owned subsidiary of TETC (USA), and an indirect wholly-owned subsidiary of the Corporation. [SIGNATURE PAGE FOLLOWS] 16A17 A=COM IN WITNESS WHEREOF, I have subscribed my name this 11th day of February, 2016. 24,4AC Preston pson Assistant Secretary 1 6 A 1 7 Azcom EXHIBIT A COMPANY ORGANIZATION CHART AECOM Delaware Corporation 100% The Earth Technology Corporation (USA) „.. Delaware Corporation 1005S AECOM Technical Services, Inc. California Corporation ••• 16A17 AKOM June 14, 2016 Ms. Evelyn Colon Procurement Strategist Collier County Procurement Services Division 3327 Tamiami Trail East Naples, FL 34112-4901 RE: Collier County-Vanderbilt Drive Bridge Replacement Project CEI Contract# 15-6418 Dear Ms. Colon, Enclosed, please find the original signed subject Professional Services Agreement. Also enclosed, please find three (3) copies of our proof of insurance coverage, E-Verify documents and proof of signatory authority for Mr. Larry Sauls. Upon final execution, please return one (1) fully executed copy to Ms. Crystal Gorman at our Fort Meyers office located at: AECOM Technical Services, Inc. Attn: Crystal Gorman 4415 Metro Parkway, Suite 404 Fort Myers, FL 33916 Please let me know if you need any additional documentation. I may be reached at (941) 417-7900 or by email at: holly.klarkowski@aecom.com. Thank you. 1,01.41 civoid6s4A4/et Holly Klarkowski Administrative Assistant/PMA, CEI Division Enclosures /hk 16A17 A:COM AFCOM, 5 899 5858 tel Poe*Montgomery Center 41 415 882 9251 fan OrP tviPrd go rp v Street Suite 900 Snn ec CA94th4 CERTIFICATE OF AUTHORITY I, Carol F. Brandenburg-Smith,the undersigned, do hereby certify that I am the Assistant Secretary of AECOM Technical Services, Inc., a California corporation(the -Corporation"), and that the Amended and Restated Corporate Bylaws of the Corporation, effective June 15, 2010, provide that: Any officer of the corporation holding the title of senior vice president or higher, or any other person designated by resolution of the board of directors, may execute contracts or other legal instruments on behalf of the corporation or its divisions. Unless so authorized by the board, no officer, agent or employee shall have any power or authority to bind the corporation by any contract or engagement or to pledge its credit or to render it liable for any purpose or in any amount. I further certify that as of August 27, 2015. the Board of Directors of the Corporation, by unanimous action, duly adopted a resolution authorizing J. Larry Sauls, P.E. of the corporation, to sign any and all contracts or amendments to contracts on behalf of the corporation. RESOLVED FURTHER,that Mr. Sauls term of office shall continue at the pleasure of the Board or until employment with the Corporation or an affiliate shall cease. I do further certify that the above resolution has not been amended or revoked and is now in full force and effect. Witness my hand and seal of the Corporation this 26th day of October 2015 ke, f a#T,Biandenburg-Smith, Assistant Secretary AECOM Technical Services,Inc