Agenda 06/14/2016 Item #16E 4 Proposed Agenda Changes
Board of County Commissioners Meeting
June 14,2016
Add On Item 10A: Recommendation to consider a proposal from the Marco Island City Council to
return County Road 92A(Goodland Road)to Collier County's jurisdiction and authorize the County
Manager to further explore this option with the Marco Island City Manager. (Commissioner Fiala's request)
Continue Item 16E4 to the June 28, 2016 BCC Meeting: Recommendation to
award Request for Proposal #16-6618, "Annual Contract for General
Contractor Services" to the following six firms: Surety Construction
Company, Bradanna, Inc., Compass Construction, Inc., William J. Varian
Construction Company, Inc., Chris Tel, and EBL Construction.
(Commissioner Taylor's request)
Move Item 16I1 to Item 13A: Miscellaneous Correspondence. (Commissioner Nance's request)
Move Item 16J2 to Item 13B: To record in the minutes of the Board of County Commissioners,the check
number(or other payment method),amount,payee,and purpose for which the referenced disbursements
were drawn for the periods between May 12 to June 1,2016 pursuant to Florida Statute 136.06.
(Commissioner Nance's request)
Move Item 16J3 to Item 13C: To provide to the Board a "Payables Report" as of June 8,2016 pursuant to
the Board's request. (Commissioner Nance's request)
Note:
Item 16A5 does not require Ex Parte Disclosure: • ' • • • • •• ' • • • • ' • • •
Recommendation to approve a Right-of-Way Easement Use Agreement to allow the owner of Lot 16,Block B,
Rock Harbor to install an approximately 18 foot long fence within the Harbor Road right-of-way,at the
eastern terminus of the road adjacent to the property. (County Attorney's request)
Item 16D14: Modify the Memorandum of Understanding document,where appropriate,to identify the
County Manager or his designee as the responsible agent that will manage the contract on behalf of the Board
of County Commissioners. (Commissioner Henning's request)
6/14/2016 8 30 AM
6/14/2016 16.E.4.
EXECUTIVE SUMMARY
Recommendation to award Request for Proposal #16-6618, "Annual Contract for General
Contractor Services" to the following six firms: Surety Construction Company, Bradanna, Inc.,
Compass Construction, Inc., William J. Varian Construction Company, Inc., Chris Tel, and EBL
Construction.
OBJECTIVE: To secure general contracting services to provide an efficient and timely response to
address maintenance and repairs to the facility infrastructure for projects under$250,000.
CONSIDERATION: The Facilities Management Division is responsible for more than 4.3 million
square feet in more than 900 structures. In order to efficiently and effectively address the maintenance
and repair items (i.e., office re-designs, restroom repairs, heating ventilation rehabilitation, door
relocations, plumbing, electrical, etc.); and/or construction projects outlined on the Capital Projects List
approved by the Board, general contractor services are used.
On behalf of all County divisions, Facilities Management and Procurement Services staff developed
Request for Proposal (RFP) #16-6618 Annual Contract for General Contractor Services. Based on
historical data,and other similar contracts approved by the Board,this competitive solicitation was issued
with the following selection criteria, as many of these projects are dependent on specialized
expertise/experience, project scheduling, quality of work or other customer critical components. The
criteria included:
• Firm Business Plan and Company Overview(5 points)
• Project History(25 points)
• Experience and Capacity of Firms(25 points)
• Specialized Expertise of Team Members and Rates(25 points)
• References(10 points)
• Local Vendor Preference(10 points)
This solicitation was issued March 10, 2016; notices were emailed to one thousand six hundred seventy-
three (1,673) firms with eighty-four (84) requests for solicitation packages. The Procurement Services
staff received proposals from nine (9) firms by the due date of April 12, 2016. According to standard
procurement procedures, a selection committee was formed to review and rank the proposals. By
consensus,the committee recommended the following firms to be awarded a contract:
1. Surety Construction Company
2.Bradanna,Inc.
3. Compass Construction,Inc.
4.William J.Varian Construction Company,Inc.
5. Chris-Tel Construction Company
6.EBL Construction
For projects between zero and three thousand ($3,000) dollars, staff will select one awarded contractor.
For projects that have a value between three thousand($3,000)to two hundred fifty thousand($250,000)
dollars, staff will notify all contractors under this contract to obtain quotes; and the work will be awarded
to the lowest responsive quote.
Staff requests that the Board award RFP#16-6618,"Annual Contract for General Contractor Services"to
the six(6)firms identified herein.
Packet Page -1320-
6/14/2016 16.E.4.
FISCAL IMPACT: The funding for each Work Order that is assigned under the approved contracts has
been approved by the Board during the annual operating and capital budget process. The annual
expenditures for these services has been between $1,900,000 and $2,100,000 annually over the past five
years.
GROWTH MANAGEMENT IMPACT: While these contracts have no direct growth management
impact,they are consistent with the County's long-term growth plans.
LEGAL CONSIDERATIONS: This item has been reviewed by the County Attorney, is approved as to
form and legality,and requires majority vote for approval. -JAK
RECOMMENDATION: That the Board of County Commissioners award RFP #16-6618, "Annual
Contract for General Contractor Services" to six firms: Surety Construction Company, Bradanna, Inc.,
Compass Construction, Inc., William J. Varian Construction Company, Inc., Chris-Tel Construction
Company, and EBL Construction and authorizes the Chairman to sign the attached contracts.
Prepared by: Margaret A.Bishop,P.E., Senior Project Manager,Facilities Management Division
Attachments:
1. Selection Committee Final Rankings
2. RFP 16-6618 Annual Contract for General Contractor Services
3. RFP 16-6618 addendum 1
4. Surety Construction Company—Contract
5. Bradanna Inc.—Contract
6. Compass Construction,Inc.—Contract
7. William J.Varian Construction Company,Inc.—Contract
8. Chris-Tel Construction Company—Contract
9. EBL Construction-Contract
Packet Page -1321-
6/14/2016 16.E.4.
COLLIER COUNTY
Board of County Commissioners
Item Number: 16.16.E.16.E.4.
Item Summary: Recommendation to award Request for Proposal#16-6618, "Annual
Contract for General Contractor Services"to the following six firms: Surety Construction
Company, Bradanna, Inc., Compass Construction, Inc., William i. Varian Construction Company,
Inc., Chris Tel, and EBL Construction.
Meeting Date: 6/14/2016
Prepared By
Name: BishopMargaret
Title:Project Manager, Senior,Facilities Management
5/19/2016 12:39:32 PM
Submitted by
Title:Project Manager, Senior,Facilities Management
Name: BishopMargaret
5/19/2016 12:39:34 PM
Approved By
Name: JonesHank
Title: Project Manager,Principal,Facilities Management
Date: 5/20/2016 3:05:18 PM
Name: pochopinpat
Title: Operations Coordinator,Administrative Services Department
Date: 5/23/2016 4:56:07 PM
Name: MarkiewiczJoanne
Title: Division Director-Procurement Services,Procurement Services
Date: 5/24/2016 10:02:46 AM
Name: LinguidiDennis
Title: Division Director-Facilities Mgmt,Facilities Management
Date: 5/24/2016 10:25:20 AM
Packet Page -1322-
6/14/2016 16.E.4.
Name: JohnsonScott
Title:Manager-Procurement,Procurement Services
Date: 5/24/2016 1:35:55 PM
Name: HerreraSandra
Title:Manager-Procurement,Procurement Services
Date: 5/24/2016 3:25:48 PM
Name: BurnsRhonda
Title:Procurement Specialist,Procurement Services
Date: 5/24/2016 5:06:31 PM
Name: KlatzkowJeff
Title: County Attorney,
Date: 5/25/2016 12:15:41 PM
Name: PriceLen
Title:Department Head-Administrative Svc,Administrative Services Department
Date: 5/31/2016 5:29:06 PM
Name: WellsLaura
Title: Management/Budget Analyst, Senior, Office of Management&Budget
Date: 6/1/2016 10:26:22 AM
Name: KlatzkowJeff
Title: County Attorney,
Date: 6/1/2016 10:50:12 AM
Name: CasalanguidaNick
Title:Deputy County Manager,County Managers Office
Date: 6/5/2016 10:45:44 AM
Packet Page-1323-
6/14/2016 16.E.4.
0 00 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0
Y x0000000• 0
E c c<i cf) �t `n m ti w
0 L12
c_ia
O. c
iz
C)
d
U)
M M co ti LO f— co
r M M co (0 (0
cons M (0 CO (fl
� M o0 T- M
Cf) N Co
-- N M 1' CO IC) aD 1%. 0)
.0,a
co d' co Cfl C) )• CO
O
O 4.+
O .0
O C
C)
▪E co c.._
O C
V Y
c cr N d' M CO U) ti CO C)
O CO CY) �,
+. .` .0
v co
a) is a) c0
m c p CI O O
CL N
r c.:":4
N � � CO 1� 00 � �
v
0 �, t.
U m 0
c
t
c I
C
c c%1‘
r M Cn CO I-e30-
C) CD m
m
C
Q
r N '1;1°.41.v.151:0
I� Cb C) CO
ce
2c)-8.E0-
C.
0)t
H
m
V C J
- J N
O C w U .C OUU nL av o f ccvaii ° C16:! O0)
wUo ; ° COZL Li��}} 1.)
- CO (6COC V ...
O• m > U c E
b 'i I UCS a) O E
1§ *k ca Q� cn IT U N U (-)
U
T�
Q0) j R O E m cC6 C w 2
V � � cocnU � Uw > Oo a
Packet Page-1324-
6/14/2016 16.E.4.
REQUEST FOR PROPOSAL
Cofer County
Administrative Services Department
Procurement Services Division
COLLIER COUNTY
BOARD OF COUNTY COMMISSIONERS
solicitation #16-6618 General Contractor Services
•
Rhonda Burns, Procurement Strategist
(239) 252-8941 (Telephone)
(239) 252-6700(Fax)
RhondaCummings@co/liergov.net(Email)
This proposal solicitation document is prepared in a Microsoft Word format. Any alterations to this document
made by the Vendor may be grounds for rejection of proposal, cancellation of any subsequent award, or any
other legal remedies available to the Collier County Government.
0
PropunamentSetvipesavisimn•3327TenuamiTrailEast•Naples,Florida34112-4901•239-25243407•www.colliergov.net/procurementservices
Packet Page-1325-
6/14/2016 16.E.4.
Table of Contents
LEGAL NOTICE 3
EXHIBIT I:SCOPE OF WORK,SPECIFICATIONS AND RESPONSE FORMAT 4
EXHIBIT II:GENERAL RFP INSTRUCTIONS 16
EXHIBIT III:COLLIER COUNTY PURCHASE ORDER TERMS AND CONDITIONS 20
EXHIBIT IV:ADDITIONAL TERMS AND CONDITIONS FOR RFP 24
ATTACHMENT 1:VENDOR'S NON-RESPONSE STATEMENT 33
ATTACHMENT 2:VENDOR CHECK LIST 34
ATTACHMENT 3:CONFLICT OF INTEREST AFFIDAVIT 35
ATTACHMENT 4:VENDOR DECLARATION STATEMENT 36
ATTACHMENT 5:AFFIDAVIT FOR CLAIMING STATUS AS A LOCAL BUSINESS 38
ATTACHMENT 6:IMMIGRATION AFFIDAVIT CERTIFICATION 39
ATTACHMENT 7:VENDOR SUBSTITUTE W—9 40
ATTACHMENT 8:INSURANCE AND BONDING REQUIREMENTS 41
ATTACHMENT 9:REFERENCE QUESTIONNAIRE 43
16-6618
RFP_Non_CCNATemplate_12222015
2
Packet Page -1326-
6/14/2016 16.E.4.
Cater County
Administrative Services Department
Procurement Services Division
Legal Notice
Sealed Proposals to provide General Contractor Services will be received until 2:30 PM Naples local
time, on April 12, 2016 at the Collier County Government, Purchasing Department, 3327 Tamiami
Trail E, Naples, FL 34112.
Solicitation
16-6618 General Contractor Services
Services to be provided may include, but not be limited to the following: complete and miscellaneous
contracting jobs that require the services of a General Contractor.
A non-mandatory pre-proposal conference will be held on March 31, 2016, commencing promptly at
10:00 AM, and will be held in the Purchasing Department Conference Room, Collier County
Government, Purchasing Department, 3327 Tamiami Trail E, Naples, FL 34112.
All statements shall be made upon the official proposal form which may be obtained on.the Collier
County Purchasing Department Online Bidding System website: www.colliergov.net/bid.
Collier County does not discriminate based on age, race, color, sex, religion, national origin, disability
or marital status.
BOARD OF COUNTY COMMISSIONERS
COLLIER COUNTY, FLORIDA,
BY: /S/ Joanne Markiewicz
Director, Procurement Services
This Public Notice was posted on the Collier County Purchasing Department website:
www.colliergov.net/purchasing and in the Lobby of Purchasing Building "G", Collier County
Government Center on March 10, 2016.
„ H
Rvc remertServices Department•3327 Tamiami Trail East•Naples,Florida 34112-4901•www.coltergov.notrpurchasing
16-6618
R F P_N o n_C C N ATe m p l a te_122 22015
3
Packet Page-1327-
6/14/2016 16.E.4.
Exhibit I: Scope of Work, Specifications and Response Format
As requested by the Collier County Procurement Services Division (hereinafter, the "Division or
Department"), the Collier County Board of County Commissioners Procurement Services Division
(hereinafter, "County") has issued this Request for Proposal (hereinafter, "RFP") with the intent of
obtaining proposals from interested and qualified Consultants in accordance with the terms,
conditions and specifications stated or attached. The Consultant, at a minimum, must achieve the
requirements of the Specifications or Scope of Work stated.
The results of this solicitation may be used by other County departments once awarded according to
the Board of County Commissioners Procurement Ordinance, as amended, and Procedures.
Brief Description of Purchase
The selected General Contractor(s) shall be responsible for knowledge of and compliance with all
relative local, state, and federal codes and regulations. The selected General Contractor(s) will also
be required to follow Collier County vertical standards, unless otherwise approved by the Facilities
Management Division (copy of current vertical standards will be included with RFP packets). The
resultant Contract will be available, but not mandatory, for use by all County Departments in need of
this service.
Historically, County departments have encumbered approximately $1,900,000 — 2,100,000 annually
over the past five (5) years. The construction services associated with the resultant contract generally
will not exceed $250,000 for any one project unless approved by the Board of County Commissioners.
Scope of Work
The selected General Contractor(s) will be responsible for providing complete construction services
for a wide range of projects, and is responsible for the overall coordination of a project. The General
Contractor (GC) provides material, labor, equipment, tools and services necessary for the project. The
GC may hire specialized subcontractors to perform all, or some portion of the construction work.
The GC must be qualified, and is directly responsible for 100% of the contracted work including all
work performed by the GC's in-house personnel or any subcontractors. In the event the General
Contractor(s) does not "self perform" any or all tasks within the specifications, and utilizes
subcontractors, the General Contractor is directly responsible for all supervision, monitoring and
compliance with one hundred percent (100%) of meeting schedule, cost, work scope plans and
specification quality in the performance of a project for the County.
GC's may be involved in:
• Construction supervision/administration;
• New construction;
• Renovations/retrofits;
• Design Build projects (generally only under$50,000);
• Demolition associated with renovations/retrofits;
• Scheduling work and subcontractors in harmony with the County's operations; and,
• Estimating cost of future projects.
16-6618
RFP_N on_CCNATem plate_12222015
4
Packet Page -1328-
6/14/2016 16.E.4.
GC responsibilities may include (these are not intended to represent the entire GC portfolio, but
rather, a sample of the various responsibilities that a GC may be requested to participate in for a
Collier County project) including but not limited to:
• Hiring various trades to complete a project;
• Applying for building permits;
• Securing the property;
• Providing temporary utilities on site;
• Managing personnel on site;
• Providing site surveying and engineering services; and,
• Disposing or recycling of construction waste, monitoring schedules and cash flows, and
maintaining accurate records.
In preparing a response/proposal, the selected GCs agree to the following:
1. Should any project that is active extend past the contract termination date, the specific work
order or purchase order shall be extended until the completion of the project and the work is
deemed accepted by the County's project manager.
2. Individual projects shall be quoted as lump sum for all work, as directed by the County's
project manager. The GC is responsible for providing a lump sum quote and agrees to the
lump sum price methodology, definitions and practices established by the Board of County
Commissioners as stated below:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are
transferred from the County to the contractor; and, as a business practice there are no hourly
or material invoices presented, rather, the contractor must perform to the satisfaction of the
County's project manager before payment for the fixed price contract is authorized.
Generally speaking, these contracts are predictable and cost certain, easy to administer for
the County and the Contractor, and foster higher levels of collaboration, and account for
more than fifty (50%) percent of public sector projects.
3. For projects that require bonding (typically over $200,000); the bonding fee may be charged
to Collier County.
4. For insurance related repairs/work, the GC may be asked to provide an itemized breakdown
of materials, labor and associated costs necessary to complete the repairs covered by the
County's insurance policy.
5. The County's project manager will follow the procedure outlined below to receive price
proposals from the awarded GC:
For projects up to three thousand ($3,000) dollars is as follows:
• County Staff will select one of the awarded contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
16-6618
R F P_N o n_C C N ATe m p l a te_12 222 015
5
Packet Page -1329-
6/14/2016 16.E.4.
For projects up to fifty thousand ($50,000) dollars is as follows:
• For projects above three thousand ($3,000) and up to $50,000: A summary of work will
be offered to all GC's under contract. The GC will respond with the price methodology
as identified by the County's project manager within seven (7) working days for non
emergency work and within twenty-four (24) hours for emergency work from the time of
the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the GC with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all GC's under contract with anticipated completion
schedules, price methodology, and may identify liquidated damages (if required).
• The GC will respond with a price methodology and the requisite quote information
requested by the County's project manager which may include Performance and
Payment Bonds requirements, within seven (7) working days for non emergency work
and within twenty-four (24) hours for emergency work from the time of the request. If
required, the Project Manager shall attach the Bond paperwork to the SAP requisition
and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuance of a purchase order.
• The work will be given to the GC with the lowest responsive lump sum quote.
6. Additional Performance and Payment Bonds Requirement: When a construction project
is in excess of$200,000 and more than thirty (30) days in duration, the Contractor(s) may be
required to provide Performance and Payment Bonds, in the form prescribed in Exhibits A,
and B, Pages A-1 through B-3, in the amount of 100% of the Contract Amount, the costs of
which is to be paid by Contractor. The Performance and Payment Bonds shall be
underwritten by a surety authorized to do business in the State of Florida and otherwise
acceptable to Owner; provided, however, the surety shall be rated as "A-" or better as to
general policy holders rating and Class V or higher rating as to financial size category and
the amount required shall not exceed 5% of the reported policy holders' surplus, all as
reported in the most current Best Key Rating Guide, published by A.M. Best Company, Inc.
of 75 Fulton Street, New York, New York 10038. Should the contract amount be less than
$500,000, the requirements of Section 287.0935, F.S. shall govern the rating and
classification of the surety.
All performance security under the subsequent contract shall be continued for a six (6)
month period beyond the final completion of the project. If the surety for any bond furnished
by Contractor is declared bankrupt, becomes insolvent, its right to do business is terminated
in the State of Florida, or it ceases to meet the requirements imposed by the Contract
Documents, the Contractor shall, within five (5) calendar days thereafter, substitute
16-6618
RFP_Non_CCNATemplate_12222015
6
Packet Page-1330-
6/14/2016 16.E.4.
Term of Contract
The contract term, if an award(s) is/are made is intended to be for two (2) years, with one (1)
additional two (2) year renewal option.
Projected Solicitation Timetable
The following projected timetable should be used as a working guide for planning purposes only.
The County reserves the right to adjust this timetable as required during the course of the RFP
process.
Event Date
Issue Solicitation Notice March 10, 2016
Last Date for Receipt of Written Questions April 6, 2016, 4:00
PM, Naples Local
Time
Pre-Proposal meeting (non-mandatory) March 31, 2016,
10:00 AM, Naples
Local Time and
Locations
Addendum Issued Resulting from Written Questions or Pre- TBA
Proposal Conference
Solicitation Deadline Date and Time April 12, 2016, 2:30
PM, Naples Local
Time
Anticipated Evaluation of Submittals April - May 2016
Anticipated Completion of Contract Negotiations May 2016
Anticipated Board of County Commissioner's Contract June 2016
Approval Date
Response Format
The Vendor/General Contractor understands and agrees to abide by all of the RFP specifications,
provisions, terms and conditions of same, and all ordinances and policies of Collier County. The
Vendor further agrees that if it is awarded a contract, the work will be performed in accordance
with the provisions, terms and conditions of the contract.
To facilitate the fair evaluation and comparison of proposals, all proposals must conform to the
guidelines set forth in this RFP.
Any portions of the proposal that do not comply with these guidelines must be so noted and
explained in the Acceptance of Conditions section of the proposal. However, any proposal that
contains such variances may be considered non-responsive.
Proposals should be prepared simply and economically, providing a straightforward concise
description of the Vendor's approach and ability to meet the County's needs, as stated in this
RFP. All proposals should be presented as described in this RFP in PDF or Microsoft Word
16-6618
RF P_Non_CC NATem plate_12222015
7
Packet Page-1331-
6/14/2016 16.E.4.
format with Tabs clearly marked. If outlined in this RFP, the utilization of recycled paper for
proposal submission is strongly encouraged.
The items listed below shall be submitted with each proposal and should be submitted in the order
shown. Each section should be clearly labeled, with pages numbered and separated by tabs.
Failure by a Vendor to include all listed items may result in the rejection of its proposal.
1. Tab I, Cover Letter/ Management Summary
Provide a cover letter, signed by an authorized officer of the firm, indicating the underlying
philosophy of the firm in providing the services stated herein. Include the name(s), telephone
number(s) and email(s) addresses of the authorized contact person(s) concerning proposal.
Submission of a signed Proposal is Vendor's certification that the Vendor will accept any
awards as a result of this RFP.
2. Tab II, GC Business Plan and Company Overview(5 points)
In this tab, include:
• The approach in coordinating GC projects that do not exceed fifty thousand ($50,000)
dollars.
• Provide a sample schedule, with milestones, for a project that does not exceed fifty
thousand ($50,000) dollars.
• Provide responses to the following items below in the format requested so that the
Selection Committee members will be provided with the same objective information for
each company for scoring purposes. Companies who do not respond to the items
below in this format will be pre-scored zero (0) points; items not completed or left blank
will be pre-scored zero (0)
1. My company has a business manual which outlines
administrative procedures.
Instructions: Enter ten (10) if the company has a
business manual. Enter zero (0) if the company does
not have a business manual.
2. My company has a drug-free workplace policy.
Instructions: Enter ten (10) if the company has a drug
free workplace policy. Enter zero (0) if the company
does not have a drug free workplace policy.
• If the answer is yes, provide a copy of that policy.
3. My company performs random drug testing.
Instructions: Enter ten (10) if the company performs
random drug testing. Enter zero (0) if the company
does not provide random drug testing.
16-6618
RF P_Non_CCNATem plate_12222015
8
Packet Page-1332-
6/14/2016 16.E.4.
TOTAL (Add items#1 -3, and place the total in the
adjacent field)
Prior to the Selection Committee reviewing proposals, the following methodology will be
applied to each General Contractors' information provided in this area:
• The County shall total each of the company's scores and create a ranking from highest
total to lowest total.
• The highest number of points will be awarded to the company who has the highest total.
• For all distribution of criteria points, the company total will be divided by the highest
company's total which will then be multiplied by the criteria points within this section to
determine the General Contractors Points Awarded. Each subsequent company's score
will be calculated in the same manner.
• Points awarded will be extended to a "whole" number(per Microsoft Excel).
For illustrative purposes only, see chart for an example of how these points would be
distributed among the six proposers.
. �Company Total
Company Score Points Awaciled
Firm ABC 30 5
Firm DEF 30 5
Firm GHI 20 3
Firm JKL 20 3
Firm MNO 20 3
Firm PQR 10 2
The Points Awarded will be distributed to the Selection Committee prior to their evaluation of
the proposals. The Selection Committee will review the proposal to ensure consistency and
completion of all tasks in the RFP, and review the Points Awarded per company. The
Selection Committee members may, at their sole discretion modify the points assigned after a
thorough review of the proposal and prior to final ranking by the final Selection Committee.
3. Tab III, Project History (25 points)
In this tab, include:
• Provide responses to the following items below in the format requested so that the
Selection Committee members will be provided with the same objective information for
each company for scoring purposes. Companies who do not respond to the items below in
this format will be pre-scored zero (0) points; items not completed or left blank will be pre-
scored zero (0)
1. Identify the number of similar projects that the company
started during this time frame (1/1/2013— 12/31/2015).
2. Of the projects identified above (in item#1), identify
how many of those projects are complete, closed and
16-6618
RF P_Non_CC NATem plate_12222015
9
Packet Page-1333-
6/14/2016 16.E.4.
all documentation turned over to the "owner."
3. Of the projects identified above (in item#2), identify
how many of those projects were completed according
to the owner's schedule (number of days).
4. Of the projects identified above (in item#2), identify
how many of those projects were completed in the
owner's outlined budget.
Subtotal (Add items 1 through 4 and enter subtotal enter in
the adjacent field)
5. Of the projects identified above (in item#1), identify
how many of those projects are not complete, closed
and all documentation has been turned over to the
"owner."
TOTAL(Subtract item 5 from the Subtotal and enter in the
adjacent field)
Prior to the Selection Committee reviewing proposals, the following methodology will be
applied to each GC's information provided in this area:
• The County shall total each of the company's scores and create a ranking from highest
total to lowest total.
• The highest number of points will be awarded to the company who has the highest
total.
• For all distribution of criteria points, the company total will be divided by the highest
company's total which will then be multiplied by the criteria points within this section to
determine the General Contractors Points Awarded. Each subsequent company's
score will be calculated in the same manner.
• Points awarded will be extended to a "whole" number (per Microsoft Excel).
For illustrative purposes only, see chart for an example of how these points would be
distributed among the six proposers.
Company Total
Company Score Points Awarded
Firm ABC 128 25
Firm DEF 125 24
Firm GI-II 92 18
Firm JKL 67 13
Firm MNO 67 13
Firm PQR 14 3
The Points Awarded will be distributed to the Selection Committee prior to their evaluation
of the proposals. The Selection Committee will review the proposal to ensure consistency
and completion of all tasks in the RFP, and review the Points Awarded per company. The
Selection Committee members may, at their sole discretion modify the points assigned
16-6618
RF P_Non_CCNATem plate_12222015
10
Packet Page -1334-
6/14/2016 16.E.4.
after a thorough review of the proposal and prior to final ranking by the final Selection
Committee.
4. Tab IV, Experience and Capacity of Firm (25 points)
Include the following information
• Provide information that outlines the process that the GC uses to assess
subcontractors' qualifications to produce the required deliverables, including abilities,
capacity, skill, and financial strength, and number of years of experience in providing
the required services.
• Describe the GC's various team members who deliver successful projects on time and
on budget. Provide at least one (1) example.
• Provide responses to the following items below in the format requested so that the
Selection Committee members will be provided with the same objective information for
each company for scoring purposes. Companies who do not respond to the items
below in this format will be pre-scored zero (0) points; items not completed or left blank
will be pre-scored zero (0).
1. As described in the solicitation document, the
company must be licensed and insured in the
State of Florida.
Instructions: Insert ten (10) if evidence of licensure
and insurance is included in the submittal; insert
zero (0) if evidence is not presented.
• Provide evidence of licenses and insurance. If
this evidence of licensure and insurance is
not provided, the County reserves the right
to no Ion•er consider the •ro•osal.
2. Identify the number of years the company has provided
General Contracting services to the public sector(under
the same name and/or the same principle owners). (number of years)
3. Identify the number of"industry awards and/or
recognitions"that the company has received from peer
group (i.e. Associated General Contractors of America or (number of awards)
one of its affiliates) in the past five (5) years (1/1/2011 -
12/31/2015).
4. Provide a list of projects that were performed in Collier
County including Collier County Government, over the
past five years 1/1/2011 — 12/31/2015). (number of Collier
County projects)
• Provide a list of those projects, the year, the business
owner and/or Collier County project manager.
TOTAL (Add items Ws 1 -4, and place the total in the adjacent � �;-
field) (TOTAL)
16-6618
R F P_Non_CC NATemplate_12222015
11
Packet Page-1335-
6/14/2016 16.E.4.
Prior to the Selection Committee reviewing proposals, the following methodology will be
applied to each company's information provided in this area:
• The County shall total each of the company's scores and create a ranking from highest
total to lowest total.
• The highest number of points will be awarded to the company who has the highest
total.
• For all distribution of criteria points, the company total will be divided by the highest
company's total which will then be multiplied by the criteria points within this section to
determine the General Contractors Points Awarded. Each subsequent company's
score will be calculated in the same manner.
• Points awarded will be extended to a "whole" number(per Microsoft Excel).
For illustrative purposes only, see chart for an example of how these points would be
distributed among the six proposers.
Company Total
Company Points nts Awarded
Firm ABC 54 25
Firm DEF 52 24
Firm GHI 36 17
Firm JKL 24 11
Firm MNO 14 6
Firm PQR 12 6
The Points Awarded will be distributed to the Selection Committee prior to their evaluation
of the proposals. The Selection Committee will review the proposal to ensure consistency
and completion of all tasks in the RFP, and review the Points Awarded per company. The
Selection Committee members may, at their sole discretion modify the points assigned
after a thorough review of the proposal and prior to final ranking by the final Selection
Committee.
5. Tab V, Specialized Expertise of Team Members and Rates (rates are for purposes of
Selection Committee evaluation only and will not be used as a final contract rate
schedule) (25 points)
In this tab, include:
• Description of the proposed contract team (to include principals of the firm) and the role
to be played by each member of the team.
• Attach brief resumes of all proposed project team members who will be involved in the
management of the total package of services, as well as the delivery of specific
services.
• Provide responses to the following seven (7) items below in the format requested so
that the Selection Committee members will be provided with the same objective
information for each company for scoring purposes. Companies who do not respond to
the items below in this format will be pre-scored zero (0) points; items not completed or
left blank will be pre-scored zero (0)
16-6618
RFP_N on_CCNATem plate_12222015
12
Packet Page-1336-
6/14/2016 16.E.4.
• This section below will be used for evaluation purposes only (for purposes of
Selection Committee evaluation only and will not be used as a final contract rate
schedule).
1 GC licensed staff members who have 10 years (or
more) of experience individually in their area of Number of Staff
expertise.
2 Provide the number of Project Managers on staff.
Number of Project
• Provide the fully burdened hourly rate (includes: Managers
overhead, profit, bond and insurance)
Rate: $
3 Provide the number of Project Superintendents on
staff. Number of
Superintendents
• Provide the fully burdened hourly rate (includes:
overhead, profit, bond and insurance)
Rate: $
4 Provide the number of Laborers on staff.
Number of Laborers
• Provide the fully burdened hourly rate (includes:
overhead, profit, bond and insurance)
Rate: $
5 Provide the number of Machine Operators on staff.
Number of Machine
• Provide the fully burdened hourly rate (includes: Operators
overhead, profit, bond and insurance)
Rate: $
6 Provide the number of Estimators on staff.
Number of
• Provide the fully burdened hourly rate (includes: Estimators
overhead, profit, bond and insurance)
Rate: $
7 Provide the number of Clerical/Administrative on
staff. Number of Clerical/
Administrative Staff
• Provide the fully burdened hourly rate (includes:
overhead, profit, bond and insurance)
16-6618
R F P_N o n_C C NATe m p I a te_122 22015
13
Packet Page-1337-
6/14/2016 16.E.4.
Rate: $
TOTAL (Add items Ws 1 —7, and place the total in
the adjacent field) (TOTAL)
Prior to the Selection Committee reviewing proposals, the following methodology will be
applied to each company's information provided in this area:
• The County shall total each of the company's scores and create a ranking from highest
total to lowest total.
• The highest number of points will be awarded to the company who has the highest
total.
• For all distribution of criteria points, the company total will be divided by the highest
company's total which will then be multiplied by the criteria points within this section to
determine the General Contractors Points Awarded. Each subsequent company's
score will be calculated in the same manner.
• Points awarded will be extended to a "whole" number(per Microsoft Excel).
For illustrative purposes only, see chart for an example of how these points would be
distributed among the six proposers.
Company Total .
Company Points Awarded
Score
Firm ABC 54 25
Firm DEF 52 24
Firm GNI 36 17
Firm JKL 24 11
Firm MNO 14 6
Firm PQR 12 6
6. Tab VI, References (10 points)
In order for the vendor to be awarded any points for this tab, the County requests that the
vendor submits five (5) completed reference forms from clients whose projects are of a similar
nature to this solicitation as a part of their proposal. The County will only use the methodology
calculations for the first five (5) references (only) submitted by the vendor in their proposal.
Selection Committee members are not permitted to complete reference forms for work that
was performed for Collier County Government.
Prior to the Selection Committee reviewing proposals, the following methodology will be
applied to each vendor's information provided in this area:
• The County shall total each of the vendor's five reference questionnaires and create a
ranking from highest number of points to lowest number of points. References marked
with an N/A (or similar notation will be given the score of zero (0)). Vendors who do not
turn in reference forms will be counted as zero (0).
• The greatest number of points allowed in this criterion will be awarded to the vendor who
has the highest score.
• The next highest vendor's number of points will be divided by the highest vendor's points
which will then be multiplied by criteria points to determine the vendor's points awarded.
Each subsequent vendor's point score will be calculated in the same manner.
16-6618
RF P_Non_CC NATem pl ate_12222015
14
Packet Page -1338-
6/14/2016 16.E.4.
• Points awarded will be extended to the whole number per Microsoft Excel.
For illustrative purposes only, see chart for an example of how these points would be
distributed among the five proposers.
Vendor Total Reference
Vendor Name Points Awarded
Score
Vendor ABC 445 10
Vendor DEF 435 10
Vendor GHI 425 10
Vendor JKL 385 9
Vendor MNO 385 9
Vendor PQR 250 6
The points awarded by vendor will be distributed to the Selection Committee prior to their
evaluation of the proposals. The Selection Committee will review the vendor's proposal to
ensure consistency and completion of all tasks in the RFP, and review the Points Awarded per
vendor. The Selection Committee may, at their sole discretion, contact references, and/or
modify the reference points assigned after a thorough review of the proposal and prior to final
ranking by the final Selection Committee.
7. Tab VII, Acceptance of Conditions
Indicate any exceptions to the general terms and conditions of the RFP, and to insurance
requirements or any other requirements listed in this RFP. If no exceptions are indicated in this
tabbed section, it will be understood that no exceptions to these documents will be considered
after the award, or if applicable, during negotiations. Exceptions taken by a Vendor may result
in evaluation point deduction(s) and/or exclusion of proposal for Selection Committee
consideration, depending on the extent of the exception(s). Such determination shall be at the
sole discretion of the County and Selection Committee.
8. Tab VIII, Required Form Submittals
• Attachment 2: Vendor Check List
• Attachment 3: Conflict of Interest Affidavit
• Attachment 4: Vendor Declaration Statement
• Attachment 5: Affidavit for Claiming Status as a Local Business
• Attachment 6: Immigration Affidavit Certification
• Attachment 7: Vendor Substitute W-9
• Attachment 8: Insurance and Bonding Requirements
• Attachment 9: Reference Questionnaire
• Other: Copy of current Class A General Contractor's License
16-6618
RF P_Non_CC NATem plate_12222015
15
Packet Page-1339-
6/14/2016 16.E.4.
Exhibit II: General RFP Instructions
1. Questions
Direct questions related to this RFP to the Collier County Purchasing Department Online Bidding
System website: www.colliergov.net/bid. Vendors must clearly understand that the only official
answer or position of the County will be the one stated on the Collier County Purchasing
Department Online Bidding System website. For general questions, please call the referenced
Procurement Strategist noted on the cover page.
2. Pre-Proposal Conference
The purpose of the pre-proposal conference is to allow an open forum for discussion and
questioning with County staff regarding this RFP with all prospective Vendors having an equal
opportunity to hear and participate. Oral questions will receive oral responses, neither of which will
be official, nor become part of the RFP. Only written responses to written questions will be
considered official, and will be included as part of this RFP as an addendum.
All prospective Vendors are strongly encouraged to attend, as, this will usually be the only pre-
proposal conference for this solicitation. If this pre-proposal conference is denoted as "mandatory",
prospective Vendors must be present in order to submit a proposal response.
3. Compliance with the RFP
Proposals must be in strict compliance with this RFP. Failure to comply with all provisions of the
RFP may result in disqualification.
4. Ambiguity, Conflict, or Other Errors in the RFP
It is the sole responsibility of the Vendor if the Vendor discovers any ambiguity, conflict,
discrepancy, omission or other error in the RFP, to immediately notify the Procurement Strategist,
noted herein, of such error in writing and request modification or clarification of the document prior
to submitting the proposal. The Procurement Strategist will make modifications by issuing a written
revision and will give written notice to all parties who have received this RFP from the Purchasing
Department.
5. Proposal, Presentation, and Protest Costs
The County will not be liable in any way for any costs incurred by any Vendor in the preparation of
its proposal in response to this RFP, nor for the presentation of its proposal and/or participation in
any discussions, negotiations, or, if applicable, any protest procedures.
6. Delivery of Proposals
All proposals are to be delivered before 2:30 PM, Naples local time, on or before April 12, 2016 to:
Collier County Government
Purchasing Department
3327 Tamiami Trail E
Naples FL 34112
Attn: Rhonda Burns, Procurement Strategist
16-6618
RF P_N on_CC NATem plate_12222015
16
Packet Page -1340-
6/14/2016 16.E.4.
The County does not bear the responsibility for proposals delivered to the Purchasing Department
past the stated date and/or time indicated, or to an incorrect address by Consultant's personnel or
by the Consultant's outside carrier. However, the Procurement Director, or designee, reserves the
right to accept proposals received after the posted close time under the following conditions:
• The tardy submission of the proposal is due to the following circumstances, which may
include but not be limited to: late delivery by commercial carrier such as Fed Ex, UPS
or courier where delivery was scheduled before the deadline.
• The acceptance of said proposal does not afford any competing firm an unfair
advantage in the selection process.
Vendors must submit one (1) paper copy clearly labeled "Master," and six (6) flash drives with
one copy of the proposal on each flash drive in Word, Excel or PDF. List the Solicitation
Number and Title on the outside of the box or envelope.
7. Validity of Proposals
No proposal can be withdrawn after it is filed unless the Vendor makes their request in writing to
the County prior to the time set for the closing of Proposals. All proposals shall be valid for a
period of one hundred eighty (180) days from the submission date to accommodate evaluation
and selection process.
8. Method of Source Selection
The County is using the Competitive Sealed Proposals methodology of source selection for this
procurement, as authorized by Ordinance Number 2013-69, as amended, establishing and
adopting the Collier County Procurement Procedures.
The County may, as it deems necessary, conduct discussions with qualified Vendors determined
to be in contention for being selected for award for the purpose of clarification to assure full
understanding of, and responsiveness to solicitation requirements.
9. Evaluation of Proposals
The County's procedure for selecting is as follows:
1. The County Manager or designee shall appoint a selection committee to review all
proposals submitted.
2. The Request for Proposal is issued.
3. Subsequent to the receipt closing date for the proposals, the Procurement professional will
review the proposals received and verify each proposal to determine if it minimally
responds to the requirements of the published RFP.
4. Selection committee meetings will be open to the public and the Procurement professional
will publicly post prior notice of such meeting(s) in the lobby of the Purchasing Building and
on the County's Procurement Services Internet site.
5. Prior to the first meeting (Organization Meeting) of the selection committee, the
Procurement professional will post a notice announcing the date, time and place of the
meeting at least three (3) working days prior to the meeting. At the initial organization
meeting, the selection committee members will receive instructions, the submitted
proposals, and establish the next selection committee meeting date and time. After the
first meeting, the Procurement professional will publically announce all subsequent
16-6618
RF P_N on_CC NATem plate_12222015
17
Packet Page -1341-
6/14/2016 16.E.4.
committee meeting dates and times. The subsequent meeting dates and times will be
posted with at least one (1) day advanced notice.
6. Selection committee members will independently review and score each proposal based
on the evaluation criteria stated in the request for proposal using the Individual Selection
Committee Score and Rank Form and prepare comments for discussion at the next
meeting. The Individual Selection Committee Score and Rank Form is merely a tool to
assist the selection committee member in their review of the proposals.
7. At the scheduled selection meeting, the members will present their independent findings /
conclusions / comments based on their reading and interpretation of the materials
presented to each other, and may ask questions of one another. At the conclusion of that
discussion, members of the public will be offered an opportunity (not to exceed three (3)
minutes)to provide comments.
8. At the conclusion of public comments (provided for in number 7), the selection committee
members will individually rank order each proposer. Collier County selection committee
members may consider all the material submitted by the Proposer and other information
Collier County may obtain to determine whether the Proposer is capable of and has a
history of successfully completing projects of this type, including, without limitation,
additional information Collier County may request, clarification of proposer information,
public comments, and/or additional credit information.
9. Once the individual ranking has been completed, the Procurement professional will direct
selection committee members to read their individual ranking publically. The Procurement
professional will record individual rankings on the Final Ranking Sheet which will
mathematically compile into an overall selection committee rank of proposers.
10. In any of the selection committee meeting deliberations, by consensus, members may
request to invite proposers in to clarify their proposals, ask for additional information,
present materials, interview, ask questions, etc. The members may consider any and all
information obtained through this method in formulating their individual ranking and
subsequent selection committee overall ranking and final ranking.
11.The selection committee's overall rank of firms in order of preference (from highest
beginning with a rank of one (1) to the lowest) will be discussed and reviewed by the
Procurement Strategist. By final consensus, and having used all information presented
(proposal, presentation, references, etc.), the selection committee members will create a
final ranking and staff will subsequently enter into negotiations. Award of the contract is
dependent upon the successful and full execution of a mutually agreed contract, pending
the final approval by the Board of County Commissioners.
The County reserves the right to withdraw this RFP at any time and for any reason, and to issue
such clarifications, modifications, and/or amendments as it may deem appropriate.
Receipt of a proposal by the County or a submission of a proposal to the County offers no rights
upon the Vendor nor obligates the County in any manner.
Acceptance of the proposal does not guarantee issuance of any other governmental approvals.
Proposals which include provisions requiring the granting of zoning variances shall not be
considered.
10. References
The County reserves the right to contact any and all references pertaining to this solicitation and
related proposal.
16-6618
RF P_N on_CCNATemplate_12222015
18
Packet Page-1342-
6/14/2016 16.E.4.
11. Proposal Selection Committee and Evaluation Factors
The County Manager shall appoint a Selection Committee to review all proposals submitted. The
factors to be considered in the evaluation of proposal responses are listed below.
Tab I, Cover Letter/Management Summary 0 Points
Tab II, Business Plan 5 Points
Tab III, Project History 25 Points
Tab IV, Experience and Capacity of Company 25 Points
Tab V, Specialized Expertise of Team Members 25 Points
Tab VI, References 10 Points
Local Vendor Preference 10 Points
TOTAL 100 Points
Tie Breaker: In the event of a tie, both in individual scoring and in final ranking, the firm with
the lowest paid dollars by Collier County to the vendor (as obtained from the County's financial
system)within the last five (5) years will receive the higher individual ranking. If there is a multiple
firm tie in either individual scoring or final ranking, the firm with the lowest volume of work shall
receive the higher ranking, the firm with the next lowest volume of work shall receive the next
highest ranking and so on.
12.Acceptance or Rejection of Proposals
The right is reserved by the County to waive any irregularities in any proposal, to reject any or all
proposals, to re-solicit for proposals, if desired, and upon recommendation and justification by
Collier County to accept the proposal which in the judgment of the County is deemed the most
advantageous for the public and the County of Collier.
Any proposal which is incomplete, conditional, obscure or which contains irregularities of any kind,
may be cause for rejection. In the event of default of the successful Vendor, or their refusal to
enter into the Collier County contract, the County reserves the right to accept the proposal of any
other Vendor or to re-advertise using the same or revised documentation, at its sole discretion.
16-6618
RF P_Non_CC NATem plate_12222015
19
Packet Page -1343-
6/14/2016 16.E.4.
Exhibit III: Collier County Purchase Order Terms and Conditions
1. Offer and to comply with all carrier
This offer is subject to cancellation by the regulations. Risk of loss of any goods
COUNTY without notice if not accepted by sold hereunder shall transfer to the
VENDOR within fourteen (14) days of COUNTY at the time and place of
issuance. delivery; provided that risk of loss prior
to actual receipt of the goods by the
2. Acceptance and Confirmation COUNTY nonetheless remain with
This Purchase Order (including all VENDOR.
documents attached to or referenced b) No charges will be paid by the COUNTY
therein) constitutes the entire agreement for packing, crating or cartage unless
between the parties, unless otherwise otherwise specifically stated in this
specifically noted by the COUNTY on the Purchase Order. Unless otherwise
face of this Purchase Order. Each delivery provided in Purchase Order, no invoices
of goods and/or services received by the shall be issued nor payments made
COUNTY from VENDOR shall be deemed to prior to delivery. Unless freight and
be upon the terms and conditions contained other charges are itemized, any
in this Purchase Order. discount will be taken on the full amount
of invoice.
No additional terms may be added and c) All shipments of goods scheduled on the
Purchase Order may not be changed except same day via the same route must be
by written instrument executed by the consolidated. Each shipping container
COUNTY. VENDOR is deemed to be on must be consecutively numbered and
notice that the COUNTY objects to any marked to show this Purchase Order
additional or different terms and conditions number. The container and Purchase
contained in any acknowledgment, invoice Order numbers must be indicated on bill
or other communication from VENDOR, of lading. Packing slips must show
notwithstanding the COUNTY'S acceptance Purchase Order number and must be
or payment for any delivery of goods and/or included on each package of less than
services, or any similar act by VENDOR. container load (LCL) shipments and/or
with each car load of equipment. The
3. Inspection COUNTY reserves the right to refuse or
All goods and/or services delivered return any shipment or equipment at
hereunder shall be received subject to the VENDOR'S expense that is not marked
COUNTY'S inspection and approval and with Purchase Order numbers.
payment therefore shall not constitute VENDOR agrees to declare to the
acceptance. All payments are subject to carrier the value of any shipment made
adjustment for shortage or rejection. All under this Purchase Order and the full
defective or nonconforming goods will be invoice value of such shipment.
returned pursuant to VENDOR'S instruction d) All invoices must contain the Purchase
at VENDOR'S expense. Order number and any other specific
information as identified on the
To the extent that a purchase order requires Purchase Order. Discounts of prompt
a series of performances by VENDOR, the payment will be computed from the date
COUNTY prospectively reserves the right to of receipt of goods or from date of
cancel the entire remainder of the Purchase receipt of invoices, whichever is later.
Order if goods and/or services provided Payment will be made upon receipt of a
early in the term of the Purchase Order are proper invoice and in compliance with
non-conforming or otherwise rejected by the Chapter 218, Fla. Stats., otherwise
COUNTY. known as the "Local Government
4. Shipping and Invoices Prompt Payment Act," and, pursuant to
a) All goods are FOB destination and must the Board of County Commissioners
be suitably packed and prepared to Purchasing Policy.
secure the lowest transportation rates
16-6618
RF P_N on_CC NATem plate_12222015
20
Packet Page -1344-
6/14/2016 16.E.4.
5. Time Is Of the Essence and transportation shall conform to all
Time for delivery of goods or performance of applicable laws, including but not limited to
services under this Purchase Order is of the the Occupational Health and Safety Act, the
essence. Failure of VENDOR to meet Federal Transportation Act and the Fair
delivery schedules or deliver within a Labor Standards Act, as well as any law or
reasonable time, as interpreted by the regulation noted on the face of the Purchase
COUNTY in its sole judgment, shall entitle Order.
the COUNTY to seek all remedies available
to it at law or in equity. VENDOR agrees to 9. Advertising
reimburse the COUNTY for any expenses No VENDOR providing goods and services
incurred in enforcing its rights. VENDOR to the COUNTY shall advertise the fact that
further agrees that undiscovered delivery of it has contracted with the COUNTY for
nonconforming goods and/or services is not goods and/or services, or appropriate or
a waiver of the COUNTY'S right to insist make use of the COUNTY'S name or other
upon further compliance with all identifying marks or property without the
specifications. prior written consent of the COUNTY'S
Purchasing Department.
6. Changes
The COUNTY may at any time and by
written notice make changes to drawings 10. Indemnification
and specifications, shipping instructions, VENDOR shall indemnify and hold harmless
quantities and delivery schedules within the the COUNTY from any and all claims,
general scope of this Purchase Order. including claims of negligence, costs and
Should any such change increase or expenses, including but not limited to
decrease the cost of, or the time required for attorneys' fees, arising from, caused by or
performance of the Purchase Order, an related to the injury or death of any person
equitable adjustment in the price and/or (including but not limited to employees and
delivery schedule will be negotiated by the agents of VENDOR in the performance of
COUNTY and VENDOR. Notwithstanding their duties or otherwise), or damage to
the foregoing, VENDOR has an affirmative property (including property of the COUNTY
obligation to give notice if the changes will or other persons), which arise out of or are
decrease costs. Any claims for adjustment incident to the goods and/or services to be
by VENDOR must be made within thirty (30) provided hereunder.
days from the date the change is ordered or
within such additional period of time as may 11. Warranty of Non-Infringement
be agreed upon by the parties. VENDOR represents and warrants that all
goods sold or services performed under this
7. Warranties Purchase Order are: a) in compliance with
VENDOR expressly warrants that the goods applicable laws; b) do not infringe any
and/or services covered by this Purchase patent, trademark, copyright or trade secret;
Order will conform to the specifications, and c)do not constitute unfair competition.
drawings, samples or other descriptions
furnished or specified by the COUNTY, and VENDOR shall indemnify and hold harmless
will be of satisfactory material and quality the COUNTY from and against any and all
production, free from defects and sufficient claims, including claims of negligence, costs
for the purpose intended. Goods shall be and expense, including but not limited to
delivered free from any security interest or attorneys' fees, which arise from any claim,
other lien, encumbrance or claim of any third suit or proceeding alleging that the
party. These warranties shall survive COUNTY'S use of the goods and/or
inspection, acceptance, passage of title and services provided under this Purchase Order
payment by the COUNTY. are inconsistent with VENDOR'S
representations and warranties in section 11
8. Statutory Conformity (a).
Goods and services provided pursuant to
this Purchase Order, and their production
16-6618
RF P_Non_CCNATem plate_12222015
21
Packet Page-1345-
6/14/2016 16.E.4.
If any claim which arises from VENDOR'S beyond their control, including, but without
breach of section 11 (a) has occurred, or is limitation to war, strikes, civil disturbances
likely to occur, VENDOR may, at the and acts of nature. When VENDOR has
COUNTY'S option, procure for the COUNTY knowledge of any actual or potential force
the right to continue using the goods or majeure or other conditions which will delay
services, or replace or modify the goods or or threatens to delay timely performance of
services so that they become non-infringing, this Purchase Order, VENDOR shall
(without any material degradation in immediately give notice thereof, including all
performance, quality, functionality or relevant information with respects to what
additional cost to the COUNTY). steps VENDOR is taking to complete
delivery of the goods and/or services to the
12. Insurance Requirements COUNTY.
The VENDOR, at its sole expense, shall
provide commercial insurance of such type 15. Assignment
and with such terms and limits as may be VENDOR may not assign this Purchase
reasonably associated with the Purchase Order, nor any money due or to become due
Order. Providing and maintaining adequate without the prior written consent of the
insurance coverage is a material obligation COUNTY. Any assignment made without
of the VENDOR. All insurance policies shall such consent shall be deemed void.
be executed through insurers authorized or
eligible to write policies in the State of 16. Taxes
Florida. Goods and services procured subject to this
Purchase Order are exempt from Florida
13. Compliance with Laws sales and use tax on real property, transient
In fulfilling the terms of this Purchase Order, rental property rented, tangible personal
VENDOR agrees that it will comply with all purchased or rented, or services purchased
federal, state, and local laws, rules, codes, (Florida Statutes, Chapter 212), and from
and ordinances that are applicable to the federal excise tax.
conduct of its business. By way of non-
exhaustive example, this shall include the 17. Annual Appropriations
American with Disabilities Act and all The COUNTY'S performance and obligation
prohibitions against discrimination on the to pay under this Purchase Order shall be
basis of race, religion, sex creed, national contingent upon an annual appropriation of
origin, handicap, marital status, or veterans' funds.
status. Further, VENDOR acknowledges
and without exception or stipulation shall be 18. Termination
fully responsible for complying with the This Purchase Order may be terminated at
provisions of the Immigration Reform and any time by the COUNTY upon 30 days
Control Act of 1986 as located at 8 U.S.C. prior written notice to the VENDOR. This
1324, et seq. and regulations relating Purchase Order may be terminated
thereto, as either may be amended. Failure immediately by the COUNTY for breach by
by the awarded firm(s) to comply with the VENDOR of the terms and conditions of this
laws referenced herein shall constitute a Purchase Order, provided that COUNTY has
breach of the award agreement and the provided VENDOR with notice of such
County shall have the discretion to breach and VENDOR has failed to cure
unilaterally terminate said agreement within 10 days of receipt of such notice.
immediately. Any breach of this provision
may be regarded by the COUNTY as a 19. General
material and substantial breach of the a) This Purchase Order shall be governed
contract arising from this Purchase Order. by the laws of the State of Florida. The
venue for any action brought to
14. Force Majeure specifically enforce any of the terms and
Neither the COUNTY nor VENDOR shall be conditions of this Purchase Order shall
responsible for any delay or failure in be the Twentieth Judicial Circuit in and
performance resulting from any cause for Collier County, Florida
16-6618
R FP_Non_CCNATem plate_12222015
22
Packet Page-1346-
6/14/2016 16.E.4.
b) Failure of the COUNTY to act associated with this Purchase Order in
immediately in response to a breach of accordance with Florida Statute Chapter
this Purchase Order by VENDOR shall 112.061, Per Diem and Travel
not constitute a waiver of breach. Expenses for Public Officers, employees
Waiver of the COUNTY by any default and authorized persons.
by VENDOR hereunder shall not be e) In the event of any conflict between or
deemed a waiver of any subsequent among the terms of any Contract
default by VENDOR. Documents related to this Purchase
c) All notices under this Purchase Order Order, the terms of the Contract
shall be sent to the respective Documents shall take precedence over
addresses on the face page by certified the terms of the Purchase Order. To the
mail, return receipt requested, by extent any terms and /or conditions of
overnight courier service, or by personal this Purchase Order duplicate or overlap
delivery and will be deemed effective the Terms and Conditions of the
upon receipt. Postage, delivery and Contract Documents, the provisions of
other charges shall be paid by the the Terms and/or Conditions that are
sender. A party may change its address most favorable to the County and/or
for notice by written notice complying provide the greatest protection to the
with the requirements of this section. County shall govern.
d) The Vendor agrees to reimbursement of
any travel expenses that may be
16-6618
RF P_No n_CCNATem plate_12222015
23
Packet Page-1347-
6/14/2016 16.E.4.
Exhibit IV: Additional Terms and Conditions for RFP
1. Insurance Requirements
The Vendor shall at its own expense, carry and maintain insurance coverage from responsible
companies duly authorized to do business in the State of Florida as set forth in the Insurance and
Bonding attachment of this solicitation. The Vendor shall procure and maintain property insurance
upon the entire project, if required, to the full insurable value of the scope of work.
The County and the Vendor waive against each other and the County's separate Vendors,
Contractors, Design Consultant, Subcontractors agents and employees of each and all of them, all
damages covered by property insurance provided herein, except such rights as they may have to the
proceeds of such insurance. The Vendor and County shall, where appropriate, require similar
waivers of subrogation from the County's separate Vendors, Design Consultants and Subcontractors
and shall require each of them to include similar waivers in their contracts.
Collier County shall be responsible for purchasing and maintaining, its own liability insurance.
Certificates issued as a result of the award of this solicitation must identify "For any and all work
performed on behalf of Collier County."
The General Liability Policy provided by Vendor to meet the requirements of this solicitation shall
name Collier County, Florida, as an additional insured as to the operations of Vendor under this
solicitation and shall contain a severability of interests provisions.
Collier County Board of County Commissioners shall be named as the Certificate Holder. The
Certificates of Insurance must state the Contract Number, or Project Number, or specific Project
description, or must read: For any and all work performed on behalf of Collier County. The
"Certificate Holder" should read as follows:
Collier County
Board of County Commissioners
Naples, Florida
The amounts and types of insurance coverage shall conform to the minimum requirements set forth
in the Insurance and Bonding attachment, with the use of Insurance Services Office (ISO) forms and
endorsements or their equivalents. If Vendor has any self-insured retentions or deductibles under
any of the below listed minimum required coverage, Vendor must identify on the Certificate of
Insurance the nature and amount of such self- insured retentions or deductibles and provide
satisfactory evidence of financial responsibility for such obligations. All self-insured retentions or
deductibles will be Vendor's sole responsibility.
Coverage(s) shall be maintained without interruption from the date of commencement of the Work
until the date of completion and acceptance of the scope of work by the County or as specified in this
solicitation, whichever is longer.
The Vendor and/or its insurance carrier shall provide 30 days written notice to the County of policy
cancellation or non-renewal on the part of the insurance carrier or the Vendor. The Vendor shall also
notify the County, in a like manner, within twenty-four (24) hours after receipt, of any notices of
expiration, cancellation, non-renewal or material change in coverage or limits received by Vendor
from its insurer and nothing contained herein shall relieve Vendor of this requirement to provide
notice. In the event of a reduction in the aggregate limit of any policy to be provided by Vendor
16-6618
R F P_N on_CC NATem pl a te_12222015
24
Packet Page -1348-
6/14/2016 16.E.4.
hereunder, Vendor shall immediately take steps to have the aggregate limit reinstated to the full
extent permitted under such policy.
Should at any time the Vendor not maintain the insurance coverage(s) required herein, the County
may terminate the Agreement or at its sole discretion shall be authorized to purchase such
coverage(s) and charge the Vendor for such coverage(s) purchased. If Vendor fails to reimburse the
County for such costs within thirty (30) days after demand, the County has the right to offset these
costs from any amount due Vendor under this Agreement or any other agreement between the
County and Vendor. The County shall be under no obligation to purchase such insurance, nor shall it
be responsible for the coverage(s) purchased or the insurance company or companies used. The
decision of the County to purchase such insurance coverage(s) shall in no way be construed to be a
waiver of any of its rights under the Contract Documents.
If the initial or any subsequently issued Certificate of Insurance expires prior to the completion of the
scope of work, the Vendor shall furnish to the County renewal or replacement Certificate(s) of
Insurance not later than ten (10) calendar days after the expiration date on the certificate. Failure of
the Vendor to provide the County with such renewal certificate(s) shall be considered justification for
the County to terminate any and all contracts.
2. Offer Extended to Other Governmental Entities
Collier County encourages and agrees to the successful vendor extending the pricing, terms and
conditions of this solicitation or resultant contract to other governmental entities at the discretion of
the successful vendor.
3. Additional Items and/or Services
Additional items and / or services may be added to the resultant contract, or purchase order, in
compliance with the Procurement Ordinance.
4. County's Right to Inspect
The County or its authorized Agent shall have the right to inspect the Vendor's facilities/project site
during and after each work assignment the Vendor is performing.
5. Vendor Performance Evaluation
The County has implemented a Vendor Performance Evaluation System for all contracts awarded in
excess of $25,000. To this end, vendors will be evaluated on their performance upon
completion/termination of this Agreement.
6. Additional Terms and Conditions of Contract
Collier County has developed standard contracts/agreements, approved by the Board of County
Commissioners (BCC). The selected Vendor shall be required to sign a standard Collier County
contract within twenty one (21) days of Notice of Selection for Award.
The resultant contract(s) may include purchase or work orders issued under one, or any combination
of price methodologies by the County's project manager:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
16-6618
RF P_Non_CC NATem pl ate_12222015
25
Packet Page -1349-
6/14/2016 16.E.4.
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized. Generally speaking, these
contracts are predictable and cost certain, easy to administer for the County and the Contractor,
and foster higher levels of collaboration, and account for more than fifty (50%) percent of public
sector projects.
The County reserves the right to include in any contract document such terms and conditions, as it
deems necessary for the proper protection of the rights of Collier County. A sample copy of this
contract is available upon request. The County will not be obligated to sign any contracts,
maintenance and/or service agreements or other documents provided by the Vendor.
The County's project manager, shall coordinate with the Vendor/Contractor the return of any surplus
assets, including materials, supplies, and equipment associated with the scope or work.
7. Payment Method
Payments are made in accordance with the Local Government Prompt Payment Act, Chapter 218,
Florida Statutes. Vendor's invoices must include:
• Purchase Order Number
• Description and quantities of the goods or services provided per instructions on the County's
purchase order or contract.
Invoices shall be sent to:
Board of County Commissioners
Clerk's Finance Department
ATTN: Accounts Payable
3299 Tamiami Trail E Ste 700
Naples FL 34112
Or emailed to: bccapclerk(p�collierclerk.com.
Collier County, in its sole discretion, will determine the method of payment for goods and/or services
as part of this agreement.
Payment methods include:
• Traditional—payment by check, wire transfer or other cash equivalent.
• Standard — payment by purchasing card. Collier County's Purchasing Card Program is
supported by standard bank credit suppliers (i.e. VISA and MasterCard), and as such, is
cognizant of the Rules for VISA Merchants and MasterCard Merchant Rules.
The County may not accept any additional surcharges (credit card transaction fees) as a result of
using the County's credit card for transactions relating to this solicitation. The County will entertain
bids clearly stating pricing for standard payment methods. An additional separate discounted price
for traditional payments may be provided at the initial bid submittal if it is clearly marked as an
"Additional Cash Discount."
Upon execution of the Contract and completion of each month's work, payment requests may be
submitted to the Project Manager on a monthly basis by the Contractor for services rendered for that
prior month. Services beyond sixty (60) days from current monthly invoice will not be considered for
payment without prior approval from the Project manager. All invoices should be submitted within
16-6618
RFP_Non_CCNATem plate_12222015
26
Packet Page -1350-
6/14/2016 16.E.4.
the fiscal year the work was performed. (County's fiscal year is October 1 - September 30.)
Invoices submitted after the close of the fiscal year will not be accepted (or processed for payment)
unless specifically authorized by the Project Manager.
Payments will be made for articles and/or services furnished, delivered, and accepted, upon receipt
and approval of invoices submitted on the date of services or within six (6) months after completion
of contract. Any untimely submission of invoices beyond the specified deadline period is subject to
non-payment under the legal doctrine of "laches" as untimely submitted. Time shall be deemed of
the essence with respect to the timely submission of invoices under this agreement.
In instances where the successful contractor may owe debts (including, but not limited to taxes or
other fees) to Collier County and the contractor has not satisfied nor made arrangement to satisfy
these debts, the County reserves the right to off-set the amount owed to the County by applying the
amount owed to the vendor or contractor for services performed of for materials delivered in
association with a contract.
Invoices shall not reflect sales tax. After review and approval, the invoice will be transmitted to the
Finance Division for payment. Payment will be made upon receipt of proper invoice and in
compliance with Chapter 218 Florida Statutes, otherwise known as the "Local Government Prompt
Payment Act." Collier County reserves the right to withhold and/or reduce an appropriate amount of
any payment for work not performed or for unsatisfactory performance of Contractual requirements.
8. Environmental Health and Safety
All Vendors and Sub vendors performing service for Collier County are required and shall comply
with all Occupational Safety and Health Administration (OSHA), State and County Safety and
Occupational Health Standards and any other applicable rules and regulations. Vendors and Sub
vendors shall be responsible for the safety of their employees and any unsafe acts or conditions that
may cause injury or damage to any persons or property within and around the work site. All firewall
penetrations must be protected in order to meet Fire Codes.
Collier County Government has authorized OSHA representatives to enter any Collier County facility,
property and/or right-of-way for the purpose of inspection of any Vendor's work operations. This
provision is non-negotiable by any department and/or Vendor.
All new electrical installations shall incorporate NFPA 70E Short Circuit Protective Device
Coordination and Arc Flash Studies where relevant as determined by the engineer.
All electrical installations shall be labeled with appropriate NFPA 70E arch flash boundary and PPE
Protective labels.
9. Licenses
The Vendor is required to possess the correct Business Tax Receipt, professional license, and any
other authorizations necessary to carry out and perform the work required by the project pursuant to
all applicable Federal, State and Local Law, Statute, Ordinances, and rules and regulations of any
kind. Additionally, copies of the required licenses must be submitted with the proposal
response indicating that the entity proposing, as well as the team assigned to the County
account, is properly licensed to perform the activities or work included in the contract
documents. Failure on the part of any Vendor to submit the required documentation may be
grounds to deem Vendor non-responsive. A Vendor, with an office within Collier County is also
required to have an occupational license.
16-6618
RFP_Non_CC NATem plate_12222015
27
Packet Page-1351-
6/14/2016 16.E.4.
All State Certified contractors who may need to pull Collier County permits or call in inspections must
complete a Collier County Contractor License registration form and submit the required fee. After
registering the license/registration will need to be renewed thereafter to remain "active" in Collier
County.
If you have questions regarding professional licenses contact the Contractor Licensing, Community
Development and Environmental Services at (239) 252-2431, 252-2432 or 252-2909. Questions
regarding required occupational licenses, please contact the Tax Collector's Office at (239) 252-
2477.
10. Principals/Collusion
By submission of this Proposal the undersigned, as Vendor, does declare that the only person or
persons interested in this Proposal as principal or principals is/are named therein and that no person
other than therein mentioned has any interest in this Proposal or in the contract to be entered into;
that this Proposal is made without connection with any person, company or parties making a
Proposal, and that it is in all respects fair and in good faith without collusion or fraud.
11. Relation of County
It is the intent of the parties hereto that the Vendor shall be legally considered an independent
Vendor, and that neither the Vendor nor their employees shall, under any circumstances, be
considered employees or agents of the County, and that the County shall be at no time legally
responsible for any negligence on the part of said Vendor, their employees or agents, resulting in
either bodily or personal injury or property damage to any individual, firm, or corporation.
12. Termination
Should the Vendor be found to have failed to perform his services in a manner satisfactory to the
County, the County may terminate this Agreement immediately for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall be
sole judge of non-performance.
13. Lobbying
All firms are hereby placed on NOTICE that the Board of County Commissioners does not wish to be
lobbied, either individually or collectively about a project for which a firm has submitted a Proposal.
Firms and their agents are not to contact members of the County Commission for such purposes as
meeting or introduction, luncheons, dinners, etc. During the process, from Proposal closing to
final Board approval, no firm or their agent shall contact any other employee of Collier County in
reference to this Proposal, with the exception of the Procurement Director or his designee(s). Failure
to abide by this provision may serve as grounds for disqualification for award of this contract to the
firm.
14. Public Records Compliance
The Vendor/Contractor agrees to comply with the Florida Public Records Law Chapter 119 (including
specifically those contractual requirements at F.S. § 119.0701(2) (a)-(d) and (3)), ordinances, codes,
rules, regulations and requirements of any governmental agencies.
16-6618
RF P_Non_CCNATem plate_12222015
28
Packet Page-1352-
6/14/2016 16.E.4.
15. Certificate of Authority to Conduct Business in the State of Florida (Florida Statute 607.1501)
In order to be considered for award, firms must be registered with the Florida Department of State
Divisions of Corporations in accordance with the requirements of Florida Statute 607.1501 and
provide a certificate of authority (www.sunbiz.orq/search.html) prior to execution of a contract. A
copy of the document may be submitted with the solicitation response and the document number
shall be identified. Firms who do not provide the certificate of authority at the time of response shall
be required to provide same within five (5) days upon notification of selection for award. If the firm
cannot provide the document within the referenced timeframe, the County reserves the right to award
to another firm.
16. Single Proposal
Each Vendor must submit, with their proposal, the required forms included in this RFP. Only one
proposal from a legal entity as a primary will be considered. A legal entity that submits a proposal as
a primary or as part of a partnership or joint venture submitting as primary may not then act as a sub-
consultant to any other firm submitting under the same RFP. If a legal entity is not submitting as a
primary or as part of a partnership or joint venture as a primary, that legal entity may act as a sub-
consultant to any other firm or firms submitting under the same RFP. All submittals in violation of this
requirement will be deemed non-responsive and rejected from further consideration.
17. Survivability
Work Orders: The Contractor agrees that any Work Order that extends beyond the expiration date
of Solicitation 16-6618 will survive and remain subject to the terms and conditions of that Agreement
until the completion or termination of this Work Order.
18. Protest Procedures
Any prospective vendor / proposer who desires to protest any aspect(s) or provision(s) of the
solicitation (including the form of the solicitation documents or procedures) shall file their protest with
the Procurement Director prior to the time of the bid opening strictly in accordance with the County's
then current purchasing ordinance and policies.
The Board of County Commissioners will make award of contract in public session. Award
recommendations will be posted outside the offices of the Purchasing Department on Wednesdays
and Thursdays. Any actual or prospective respondent who desires to formally protest the
recommended contract award must file a notice of intent to protest with the Procurement Director
within two (2) calendar days (excluding weekends and County holidays) of the date that the
recommended award is posted.
Upon filing of said notice, the protesting party will have five (5) days to file a formal protest and will be
given instructions as to the form and content requirements of the formal protest. A copy of the
"Protest Policy" is available at the office of the Procurement Director.
19. Public Entity Crime
A person or affiliate who has been placed on the convicted vendor list following a conviction for a
public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or
services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity
for the construction or repair of a public building or public work; may not submit bids, proposals, or
replies on leases of real property to a public entity; may not be awarded or perform work as a
16-6618
R F P_N o n_C C N ATe m p l a te_12 222 015
29
Packet Page-1353-
6/14/2016 16.E.4.
contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not
transact business with any public entity in excess of the threshold amount provided in s. 287.017 for
CATEGORY TWO for a period of 36 months following the date of being placed on the convicted
vendor list.
20. Security and Background Checks
If required, Vendor/ Contractor/ Proposer shall be responsible for the costs of providing background
checks by the Collier County Facilities Management Division, and drug testing for all employees that
shall provide services to the County under this Agreement. This may include, but not be limited to,
checking federal, state and local law enforcement records, including a state and FBI fingerprint
check, credit reports, education, residence and employment verifications and other related records.
Contractor shall be required to maintain records on each employee and make them available to the
County for at least four(4) years.
21. Conflict of Interest
Vendor shall complete the Conflict of Interest Affidavit included as an attachment to this RFP
document. Disclosure of any potential or actual conflict of interest is subject to County staff review
and does not in and of itself disqualify a firm from consideration. These disclosures are intended to
identify and or preclude conflict of interest situations during contract selection and execution.
22. Prohibition of Gifts to County Employees
No organization or individual shall offer or give, either directly or indirectly, any favor, gift, loan, fee,
service or other item of value to any County employee, as set forth in Chapter 112, Part III, Florida
Statutes, the current Collier County Ethics Ordinance and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a. Prohibition by
the individual, firm, and/or any employee of the firm from contact with County staff for a specified
period of time; b. Prohibition by the individual and/or firm from doing business with the County for a
specified period of time, including but not limited to: submitting bids, RFP, and/or quotes; and, c.
immediate termination of any contract held by the individual and/or firm for cause.
23. Immigration Affidavit Certification
Statutes and executive orders require employers to abide by the immigration laws of the United
States and to employ only individuals who are eligible to work in the United States.
The Employment Eligibility Verification System (E-Verify) operated by the Department of Homeland
Security (DHS) in partnership with the Social Security Administration (SSA), provides an Internet-
based means of verifying employment eligibility of workers in the United States; it is not a substitute
for any other employment eligibility verification requirements. The program will be used for Collier
County formal Invitations to Bid (ITB) and Request for Proposals (RFP) including professional
services and construction services.
Exceptions to the program:
• Commodity based procurement where no services are provided.
• Where the requirement for the affidavit is waived by the Board of County Commissioners
Vendors / Bidders are required to enroll in the E-Verify program, and provide acceptable evidence of
their enrollment, at the time of the submission of the vendor's/bidder's proposal. Acceptable
evidence consists of a copy of the properly completed E-Verify Company Profile page or a copy of
16-6618
RF P_Non_CC NATem plate_12222015
30
Packet Page-1354-
6/14/2016 16.E.4.
the fully executed E-Verify Memorandum of Understanding for the company. Vendors are also
required to provide the Collier County Purchasing Department an executed affidavit certifying they
shall comply with the E-Verify Program. The affidavit is attached to the solicitation documents. If the
BidderNendor does not comply with providing both the acceptable E-Verify evidence and the
executed affidavit the bidder's/vendor's proposal may be deemed non-responsive.
Additionally, vendors shall require all subcontracted vendors to use the E-Verify system for all
purchases not covered under the "Exceptions to the program" clause above.
For additional information regarding the Employment Eligibility Verification System (E-Verify) program
visit the following website: http://www.dhs.gov/E-Verifv. It shall be the vendor's responsibility to
familiarize themselves with all rules and regulations governing this program.
Vendor acknowledges, and without exception or stipulation, any firm(s) receiving an award shall be
fully responsible for complying with the provisions of the Immigration Reform and Control Act of 1986
as located at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended and
with the provisions contained within this affidavit. Failure by the awarded firm(s) to comply with the
laws referenced herein or the provisions of this affidavit shall constitute a breach of the award
agreement and the County shall have the discretion to unilaterally terminate said agreement
immediately.
24. Collier County Local Preference Policy
Collier County provides an incentive to local business to enhance the opportunities of local
businesses in the award of County contracts. In the evaluation of proposals, the County rewards
Vendors for being a local business by granting a ten (10) points incentive in the evaluation criterion
points.
Local business means the vendor has a current Business Tax Receipt issued by the Collier County
Tax Collector for at least one year prior to bid or proposal submission to do business within Collier
County, and that identifies the business with a permanent physical business address located within
the limits of Collier County from which the vendor's staff operates and performs business in an area
zoned for the conduct of such business. A Post Office Box or a facility that receives mail, or a non-
permanent structure such as a construction trailer, storage shed, or other non-permanent structure
shall not be used for the purpose of establishing said physical address. In addition to the foregoing, a
vendor shall not be considered a "local business" unless it contributes to the economic development
and well-being of Collier County in a verifiable and measurable way. This may include, but not be
limited to, the retention and expansion of employment opportunities, support and increase to the
County's tax base, and residency of employees and principals of the business within Collier County.
Vendors shall affirm in writing their compliance with the foregoing at the time of submitting their bid or
proposal to be eligible for consideration as a "local business" under this section. A vendor who
misrepresents the Local Preference status of its firm in a proposal or bid submitted to the County will
lose the privilege to claim Local Preference status for a period of up to one year.
Under this solicitation proposers desiring to receive local preference will be invited and required to
affirmatively state and provide documentation as set forth in the solicitation in support of their
status as a local business. Any proposer who fails to submit sufficient documentation with their
proposal offer shall not be granted local preference consideration for the purposes of that specific
contract award. Except where federal or state law, or any other funding source, mandates to the
contrary, Collier County and its agencies and instrumentalities, will give preference to local
businesses in the following manner.
For all purchases of commodities and services procured through a competitive proposal process
16-6618
RF P_Non_CC NATem plate_12222015
31
Packet Page-1355-
6/14/2016 16.E.4.
and not otherwise exempt from this local preference section, the solicitation shall include a
weighted criterion for local preference that equals 10 percent of the total points in the evaluation
criteria published in the solicitation. Purchases of professional services as defined and identified
under subsection 116.2 (which are subject to Section 287.055, F.S.) and subsection 116.3 (which
are subject to Section 11.45, F.S.) shall not be subject to this local preference section.
The vendor must complete and submit with their proposal response the Affidavit for Claiming Status
as a Local Business which is included as part of this solicitation.
Failure on the part of a vendor to submit this Affidavit with their proposal response will
preclude said Vendor from being considered for local preference under this solicitation.
A vendor who misrepresents the Local Preference status of its firm in a proposal or bid submitted to
the County will lose the privilege to claim Local Preference status for a period of up to one year.
16-6618
RF P_Non_CCNATem plate_12222015
32
Packet Page-1356-
6/14/2016 16.E.4.
Co ,er County
Administrative Services Department
Procurement Services Division
Attachment 1: Vendor's Non-Response Statement
The sole intent of the Collier County Purchasing Department is to issue solicitations that are clear,
concise and openly competitive. Therefore, we are interested in ascertaining reasons for prospective
Vendors not wishing to respond to this solicitation. If your firm is not responding to this RFP, please
indicate the reason(s) by checking the item(s) listed below and return this form via email or fax, noted on
the cover page, or mail to Collier County Government, Purchasing Department, 3327 Tamiami Trail E,
Naples, FL 34112.
We are not responding to Solicitation 16-6618 General Contractor Services for the following
reason(s):
❑ Services requested not available through our company.
❑ Our firm could not meet specifications/scope of work.
❑ Specifications/scope of work not clearly understood or applicable (too vague, rigid, etc.)
❑ Project is too small.
❑ Insufficient time allowed for preparation of response.
❑ Incorrect address used. Please correct mailing address:
❑ Other reason(s):
Name of Firm:
Address:
City, State, Zip:
Telephone:
Email:
Representative Signature:
Representative Name: Date
16-6618
RF P_Non_CC NATem plate_12222015
33
Packet Page -1357-
6/14/2016 16.E.4.
Cotter County
Administrative Services Department
Procurement Services Division
Attachment 2: Vendor Check List
IMPORTANT: THIS SHEET MUST BE SIGNED. Please read carefully, sign in the spaces
indicated and return with your Proposal. Vendor should check off each of the following items as the
necessary action is completed:
❑ The Proposal has been signed.
❑ All applicable forms have been signed and included, along with licenses to complete the
requirements of the project.
❑ Any addenda have been signed and included.
❑ The mailing envelope has been addressed to:
Collier County Government
Purchasing Department
3327 Tamiami Trail E
Naples FL 34112
Attn: Rhonda Burns, Procurement Strategist
❑ The mailing envelope must be sealed and marked with Solicitation 16-6618 General Contractor
Services and April 12, 2016.
❑ The Proposal will be mailed or delivered in time to be received no later than the specified due date
and time. (Otherwise Proposal cannot be considered.)
❑ If submitting a manual bid, include any addenda (initialed and dated noting understanding and
receipt). If submitting bid electronically, bidder will need to download all related documents on
www.colliergov.net/bid. The system will date and time stamp when the addendum files were
downloaded.
ALL COURIER-DELIVERED PROPOSALS MUST HAVE THE RFP NUMBER AND TITLE ON THE
OUTSIDE OF THE COURIER PACKET.
Name of Firm:
Address:
City, State, Zip:
Telephone:
Email:
Representative Signature:
Representative Name: Date
16-6618
R F P_N o n_C C N AT e m p I ate_12222015
34
Packet Page-1358-
6/14/2016 16.E.4.
COIL County
Administrative Services Department
Procurement Services Division
Attachment 3: Conflict of Interest Affidavit
By the signature below, the firm (employees, officers and/or agents) certifies, and hereby discloses, that,
to the best of their knowledge and belief, all relevant facts concerning past, present, or currently planned
interest or activity (financial, contractual, organizational, or otherwise) which relates to the proposed
work; and bear on whether the firm (employees, officers and/or agents) has a possible conflict have been
fully disclosed.
Additionally, the firm (employees, officers and/or agents) agrees to immediately notify in writing the
Procurement Director, or designee, if any actual or potential conflict of interest arises during the contract
and/or project duration.
Firm:
Signature and Date:
Print Name
Title of Signatory
State of
County of
SUBSCRIBED AND SWORN to before me this day of
20
by , who is personally known to me to be the
for the Firm, OR who produced the following
identification
Notary Public
My Commission Expires
16-6618
R F P_N o n_C C N ATe m p l a te_12 222015
35
Packet Page-1359-
6/14/2016 16.E.4.
Co ter County
Administrative Services Department
Procurement Services Division
Attachment 4: Vendor Declaration Statement
•
BOARD OF COUNTY COMMISSIONERS
Collier County Government Complex
Naples, Florida 34112
RE: Solicitation: 16-6618 General Contractor Services
Dear Commissioners:
The undersigned, as Vendor declares that this proposal is made without connection or arrangement with
any other person and this proposal is in every respect fair and made in good faith, without collusion or
fraud.
The Vendor agrees, if this proposal is accepted, to execute a Collier County document for the purpose of
establishing a formal contractual relationship between the firm and Collier County, for the performance of
all requirements to which the proposal pertains. The Vendor states that the proposal is based upon the
proposal documents listed by Solicitation: 16-6618 General Contractor Services.
(Proposal Continued on Next Page)
16-6618
RFP_Non_CC NATem plate_12222015
36
Packet Page-1360-
6/14/2016 16.E.4.
PROPOSAL CONTINUED
IN WITNESS WHEREOF, WE have hereunto subscribed our names on this day of , 20
in the County of , in the State of
Firm's Legal Name:
Address:
City, State, Zip Code:
Florida Certificate of
Authority Document Number:
Federal Tax Identification
Number
CCR#or CAGE Code
Telephone:
FAX:
Signature by:
(Typed and written)
Title:
Additional Contact Information
Send payments to:
(required if different from above) Company name used as payee •
Contact name:
Title:
Address:
City, State,ZIP
Telephone:
FAX:
Email:
Office servicing Collier
County to place orders
(required if different from above)
Contact name:
Title:
Address:
City, State,ZIP
Telephone: Email
16-6618
RFP_Non_CC NATem plate_12222015
37
Packet Page-1361-
6/14/2016 16.E.4.
Corer County
Administrative Services Department
Procurement Services Division
Attachment 5: Affidavit for Claiming Status as a Local Business
Solicitation: 16-6618 General Contractor Services (Check Appropriate Boxes Below)
State of Florida(Select County if Vendor is described as a Local Business
❑ Collier County
❑ Lee County
Vendor affirms that it is a local business as defined by the Purchasing Policy of the Collier County Board of County
Commissioners and the Regulations Thereto. As defined in Section XI of the Collier County Purchasing Policy:
Local business means the vendor has a current Business Tax Receipt issued by the Collier County Tax Collector
for at least one year prior to bid or proposal submission to do business within Collier County, and that identifies the
business with a permanent physical business address located within the limits of Collier County from which the
vendor's staff operates and performs business in an area zoned for the conduct of such business. A Post Office
Box or a facility that receives mail, or a non-permanent structure such as a construction trailer, storage shed, or
other non-permanent structure shall not be used for the purpose of establishing said physical address. In addition
to the foregoing, a vendor shall not be considered a"local business" unless it contributes to the economic
development and well-being of Collier County in a verifiable and measurable way. This may include, but not be
limited to,the retention and expansion of employment opportunities, support and increase to the County's tax base,
and residency of employees and principals of the business within Collier County. Vendors shall affirm in writing
their compliance with the foregoing at the time of submitting their bid or proposal to be eligible for consideration as
a"local business" under this section. A vendor who misrepresents the Local Preference status of its firm in a
proposal or bid submitted to the County will lose the privilege to claim Local Preference status for a period of up to
one year.
Vendor must complete the following information:
Year Business Established in ECollier County or❑ Lee County:
Number of Employees (Including Owner(s)or Corporate Officers):
Number of Employees Living in ❑ Collier County or❑ Lee (Including Owner(s)or Corporate Officers):
If requested by the County, vendor will be required to provide documentation substantiating the information given in
this affidavit. Failure to do so will result in vendor's submission being deemed not applicable.
Vendor Name: Date:
Collier or Lee County Address:
Signature: Title:
STATE OF FLORIDA
❑ COLLIER COUNTY ❑ LEE COUNTY
Sworn to and Subscribed Before Me, a Notary Public, for the above State and County, on this Day of
, 20
Notary Public
My Commission Expires:
(AFFIX OFFICIAL SEAL)
16-6618
R F P_N o n_C C N ATe m p l a te_122 2 2015
38
Packet Page -1362-
6/14/2016 16.E.4.
CIL County
Administrative Services Department
Procurement Services Division
Attachment 6: Immigration Affidavit Certification
Solicitation:16-6618 General Contractor Services
This Affidavit is required and should be signed, notarized by an authorized principal of the firm and submitted with
formal Invitations to Bid (ITB's)and Request for Proposals (RFP)submittals. Further, Vendors/Bidders are
required to enroll in the E-Verify program, and provide acceptable evidence of their enrollment, at the time of the
submission of the vendor's/bidder's proposal. Acceptable evidence consists of a copy of the properly completed E-
Verify Company Profile page or a copy of the fully executed E-Verify Memorandum of Understanding for the
company. Failure to include this Affidavit and acceptable evidence of enrollment in the E-Verify program,.
may deem the Vendor/Bidder's proposal as non-responsive.
Collier County will not intentionally award County contracts to any vendor who knowingly employs unauthorized
alien workers, constituting a violation of the employment provision contained in 8 U.S.C. Section 1324 a(e)Section
274A(e)of the Immigration and Nationality Act("INA").
Collier County may consider the employment by any vendor of unauthorized aliens a violation of Section 274A(e)
of the INA. Such Violation by the recipient of the Employment Provisions contained in Section 274A(e)of the INA
shall be grounds for unilateral termination of the contract by Collier County.
Vendor attests that they are fully compliant with all applicable immigration laws(specifically to the 1986 Immigration
Act and subsequent Amendment(s))and agrees to comply with the provisions of the Memorandum of
Understanding with E-Verify and to provide proof of enrollment in The Employment Eligibility Verification System
(E-Verify), operated by the Department of Homeland Security in partnership with the Social Security Administration
at the time of submission of the Vendor's/ Bidder's proposal.
Company Name
Print Name Title
Signature Date
State of
County of
The foregoing instrument was signed and acknowledged before me this day of
20_, by
who has produced as identification.
(Print or Type Name) (Type of Identification and Number)
Notary Public Signature
Printed Name of Notary Public
Notary Commission Number/Expiration
The signee of this Affidavit guarantees, as evidenced by the sworn affidavit required herein, the truth and accuracy
of this affidavit to interrogatories hereinafter made.
16-6618
RF P_N on_CCNATem plate_12222015
39
Packet Page-1363-
6/14/2016 16.E.4.
Co ter County
Administrative Services Department
Procurement Services Division
Attachment 7: Vendor Substitute W—9
Request for Taxpayer Identification Number and Certification
In accordance with the Internal Revenue Service regulations, Collier County is required to collect the following
information for tax reporting purposes from individuals and companies who do business with the County (including
social security numbers if used by the individual or company for tax reporting purposes). Florida Statute
119.071(5) require that the county notify you in writing of the reason for collecting this information, which will be
used for no other purpose than herein stated. Please complete all information that applies to your business and
return with your quote or proposal.
1. General Information (provide all information)
Taxpayer Name
(as shown on income tax return)
Business Name
(if different from taxpayer name)
Address City
State Zip
Telephone FAX Email
Order Information Remit/Payment Information
Address Address
City State Zip City State Zip
FAX FAX
Email Email
2. Company Status (check only one)
_Individual/Sole Proprietor _Corporation Partnership
Tax Exempt (Federal income tax-exempt entity _Limited Liability Company
under Internal Revenue Service guidelines IRC
501 (c)3) Enter the tax classification
(D=Disregarded Entity, C= Corporation, P=Partnership)
3. Taxpayer Identification Number(for tax reporting purposes only)
Federal Tax Identification Number(TIN)
(Vendors who do not have a TIN,will be required to provide a social security number prior to an award of the contract.)
4. Sign and Date Form
Certification: Under penalties of perjury, I certify that the information shown on this form is correct to my knowledge.
Signature Date
Title Phone Number
16-6618
R F P_N o n_C C NATe m p l a te_12 222015
40
Packet Page-1364-
6/14/2016 16.E.4.
Corner C.Amvity
Administrative Services Department
Procurement Services Division
Attachment 8: Insurance and Bonding Requirements
Insurance/Bond Type Required Limits
1. ®Worker's Statutory Limits of Florida Statutes, Chapter 440 and all Federal Government
Compensation Statutory Limits and Requirements
2. ® Employer's Liability $1.000,000 single limit per occurrence
3. ® Commercial General Bodily Injury and Property Damage
Liability(Occurrence Form)
patterned after the current $1,000.000 single limit per occurrence, $2,000,000 aggregate for Bodily Injury
ISO form Liability and Property Damage Liability. This shall include Premises and
Operations; Independent Contractors; Products and Completed Operations
and Contractual Liability
4. ® Indemnification To the maximum extent permitted by Florida law, the
Contractor/Company/Consultant shall indemnify and hold harmless Collier
County, its officers and employees from any and all liabilities, damages,
losses and costs, including, but not limited to, reasonable attorneys'fees and
paralegals'fees, to the extent caused by the negligence, recklessness, or
intentionally wrongful conduct of the Contractor/Company/Consultant or
anyone employed or utilized by the Contractor/Company/Consultant in the
performance of this Agreement. This indemnification obligation shall not be
construed to negate, abridge or reduce any other rights or remedies which
otherwise may be available to an indemnified party or person described in this
paragraph. This section does not pertain to any incident arising from the sole
negligence of Collier County.
4. ®Automobile Liability $500.000 Each Occurrence; Bodily Injury& Property Damage,
Owned/Non-owned/Hired; Automobile Included
5. ❑ Other insurance as ❑Watercraft $ Per Occurrence
noted:
❑ United States Longshoreman's and Harborworker's Act coverage shall be
maintained where applicable to the completion of the work.
$ Per Occurrence
❑ Maritime Coverage(Jones Act)shall be maintained where applicable to
the completion of the work.
$ Per Occurrence
0 Aircraft Liability coverage shall be carried in limits of not less than
$5,000,000 each occurrence if applicable to the completion of the Services
under this Agreement.
$ Per Occurrence
❑ Pollution $ Per Occurrence
❑ Professional Liability $ Per Occurrence
• $ 500,000 each claim and in the aggregate
• $1,000,000 each claim and in the aggregate
• $2,000,000 each claim and in the aggregate
O Professional Liability $ per claim and in
the aggregate
Packet Page -1365-
6/14/2016 16.E.4.
• $1,000,000 per claim and in the aggregate
• $2,000,000 per claim and in the aggregate
❑Valuable Papers Insurance $ Per Occurrence
6. E Bid bond (if applicaple) Shall be submitted with proposal response in the form of certified funds,
cashiers'check or an irrevocable letter of credit, a cash bond posted with the
County Clerk, or proposal bond in a sum equal to 5% of the cost proposal. All
checks shall be made payable to the Collier County Board of County
Commissioners on a bank or trust company located in the State of Florida and
insured by the Federal Deposit Insurance Corporation.
7. E Performance and For projects in excess of$200,000, bonds shall be submitted with the
Payment Bonds(if executed contract by Proposers receiving award, and written for 100% of the
applicaple) Contract award amount, the cost borne by the Proposer receiving an award.
The Performance and Payment Bonds shall be underwritten by a surety
authorized to do business in the State of Florida and otherwise acceptable to
Owner; provided, however,the surety shall be rated as"A-"or better as to
general policy holders rating and Class V or higher rating as to financial size
category and the amount required shall not exceed 5% of the reported policy
holders' surplus, all as reported in the most current Best Key Rating Guide,
published by A.M. Best Company, Inc. of 75 Fulton Street, New York, New
York 10038.
8. E Company shall ensure that all subcontractors comply with the same insurance requirements that he is
required to meet. The same Company shall provide County with certificates of insurance meeting the
required insurance provisions.
9. E Collier County must be named as "ADDITIONAL INSURED" on the Insurance Certificate for
Commercial General Liability where required.
10. E The Certificate Holder shall be named as Collier County Board of County Commissioners, OR, Board
of County Commissioners in Collier County, OR Collier County Government, OR Collier County. The
Certificates of Insurance must state the Contract Number, or Project Number, or specific Project
description, or must read: For any and all work performed on behalf of Collier County.
11. E Thirty (30) Days Cancellation Notice required.
Company's Insurance Statement
We understand the insurance requirements of these specifications and that the evidence of insurability may be required
within five(5)days of the award of this solicitation.
Name of Company Date
Company Signature
Print Name
Insurance Agency
Agent Name Telephone Number
16-6618
RFP_Non_CCNATem plate_12222015
42
Packet Page -1366-
6/14/2016 16.E.4.
Cotter County
Administrative Services Department
Procurement Services Division
Attachment 9: Reference Questionnaire
Solicitation: 16-6618 General Contractor Services
Reference Questionnaire for:
(Name of Company Requesting Reference Information)
(Name of Individuals Requesting Reference Information)
Name: Company:
(Evaluator completing reference questionnaire) (Evaluator's Corn pany completing reference)
Email: FAX: Telephone:
Collier County is implementing a process that collects reference information on firms and their key personnel to be used
in the selection of firms to perform this project. The Name of the Company listed in the Subject above has listed you as
a client for which they have previously performed work. Please complete the survey. Please rate each criteria to the
best of your knowledge on a scale of 1 to 10, with 10 representing that you were very satisifed (and would hire the
firm/individual again)and 1 representing that you were very unsatisfied (and would never hire the firm/indivdival again).
If you do not have sufficient knowledge of past performance in a particular area, leave it blank and the item or form will
be scored "0."
Project Description: Completion Date:
Project Budget: Project Number of Days:
Change Orders- Dollars Added : Change Orders-Days Added:
Item Citeria Score
1 Ability to manage the project costs(minimize change orders to scope).
2 Ability to maintain project schedule(complete on-time or early).
3 Quality of work.
4 Quality of consultative advice provided on the project.
5 Professionalism and ability to manage subcontractors!.
6 Project administration (completed documents, final invoice, final product turnover;
invoices; manuals or going forward documentation, etc.)
7 Ability to verbally communicate and document information clearly and succinctly.
8 Abiltity to manage risks and unexpected project circumstances.
9 Ability to follow contract documents, policies, procedures, rules, regulations, etc.
10 Overall comfort level with hiring the company in the future (customer satisfaction).
TOTAL SCORE OF ALL ITEMS
Please FAX this completed survey to: By
16-6618
R F P_N o n_C C NATe m p l a t e_12 222015
43
Packet Page -1367-
6/14/2016 16.E.4.
Goiter County Email: rhondaburns@colliergov.net
Administrative Services Department Telephone: (239) 252-8941
Procurement services Division FAX: (239)252-6700
ADDENDUM 1
Memorandum
Date: April 11, 2016
From: Rhonda Burns, FCCN, CPPB, Procurement Strategist
To: Interested Bidders
Subject: Addendum# 1
Solicitation#and Title 16-6618 General Contractor Services
The following correction is issued as an addendum identifying the following change (s)for the
referenced solicitation:
ADD: The following bolded underlined language:
For projects up to fifty thousand ($50,000) dollars is as follows:
• For proiects above three thousand ($3,000) and up to $50,000: A summary of work
will be offered to all GC's under contract. The GC will respond with the price
methodology as identified by the County's project manager within seven (7) working
days or as a time agreed to by the County's project manager for non emergency
work and within twenty-four (24) hours for emergency work from the time of the
request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work
shall not commence without the issuance of a purchase order.
• The work will be given to the GC with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two
hundred fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all GC's under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages (if
required).
• The GC will respond with a price methodology and the requisite quote information
requested by the County's project manager which may include Performance and
Payment Bonds requirements, within seven (7) working days or as a time agreed to
by the County's project manager for non emergency work and within twenty-four
(24) hours for emergency work from the time of the request. If required, the Project
Manager shall attach the Bond paperwork to the SAP requisition and forward the
original paperwork to Procurement Services.
Addendum 1
Packet Page -1368-
6/14/2016 16.E.4.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work
may not commence without the issuance of a purchase order.
• The work will be given to the GC with the lowest responsive lump sum quote.
If you require additional information please post a question on the Online Bidding site or
contact me using the above contact information.
c: Hank Jones, Principal Project Manager, Facilities Management Division
Please sign below and return a copy of this Addendum with your submittal for the above referenced
solicitation.
(Signature) r Date
(Name of Firm)
Packet Page-1369-
6/14/2016 16.E.4.
AGREEMENT 16-6618
for
General Contractor Services
THIS AGREEMENT is made and entered into this day of , 2016, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner") and Surety Construction
Company, authorized to do business in the State of Florida, whose business address is 6640 Willow
Park Drive, Naples, Florida 34109 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. TERM AND COMMENCEMENT. The Agreement shall be for a two (2) year period, commencing
on date of award by the Collier County Board of County Commissioners, and terminating until
such time as all outstanding Work Orders issued prior to the expiration of the Agreement period
have been completed or terminated.
The County may, at its discretion and with the consent of the Contractor, renew the Agreement
under all of the terms and conditions contained in this Agreement for one (1) additional two (2)
year term. The County shall give the Contractor written notice of the County's intention to renew
the Agreement term not less than ten (10) days prior to the end of the Agreement term.
The County Manager, or his designee, may, at his discretion, extend the Agreement under all of
the terms and conditions contained in this Agreement for up to one hundred eighty (180) days.
The Contractor shall commence the Work upon issuance of a Work Order accompanied by a
Notice to Proceed.
2. STATEMENT OF WORK. The Board of County Commissioners deemed six (6) firms to be
qualified and awarded an Agreement to each firm. Each awardee will enter into an Agreement to
provide complete services for General Contractor Services on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP#16-6618 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement.
2.1 The execution of this Agreement shall not be a commitment to the Contractor that any Work
will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
procedure to obtain Work and all Work undertaken by Contractor for Owner pursuant to this
Agreement during the term and any extension of the term of this Agreement. Any County Agency
may utilize the services offered under this Agreement, provided sufficient funds are included in the
budget(s).
2.2 The procedure for obtaining Work under this Agreement is as follows:
Page -1-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page -1370-
6/14/2016 16.E.4.
For projects with a value up to three thousand ($3,000) dollars is as follows:
• County Staff will select one of the awarded Contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
For projects above three thousand ($3,000) and up to fifty thousand ($50,000) dollars is
as follows:
• A summary of work will be offered to all Contractors under contract. The Contractors will
respond by providing fixed price, lump sum quote following the price methodology in
Section 3.1 within seven (7) working days or as a time agreed to by the County's project
manager for non emergency work and within twenty-four (24) hours for emergency work
from the time of the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all Contractors under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages, if
required.
• The Contractors will respond by providing fixed price, lump sum quote following the price
methodology in Section 3.1 and the requisite quote information requested by the County's
project manager which may include Performance and Payment Bonds requirements,
within seven (7) working days or as a time agreed to by the County's project manager for
non emergency work and within twenty-four (24) hours for emergency work from the time
of the request. If required, the Project Manager shall attach the Bond paperwork to the
SAP requisition and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
Procedures for projects with a value of$250,000 and above are as follows:
• This Agreement is limited for work or projects with an estimated initial value up to
$250,000. This value may be increased after the award by Change Orders for
unanticipated difficulties, work or costs, as set forth in the County's Procurement
Ordinance. Work or projects with an estimated initial value in excess of $250,000 are
outside of the scope of this Agreement, will be competitively bid in accordance with the
County's Procurement Ordinance and will require Board of County Commissioners
approval.
Page -2-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1371-
6/14/2016 16.E.4.
For each awarded Project, as part of the Contract Documents or in each Summary of Work or
Request for Quotation, the Owner reserves the right to specify: the period of completion; collection
of liquidated damages in the event of late completion.
2.3 This Agreement contains the entire understanding between the parties and any modifications
to this Agreement shall be mutually agreed upon in writing by the Contractor and the County, in
compliance with the Procurement Ordinance, as amended and Procurement Procedures in effect
at the time such services are authorized.
2.4 This Agreement shall be the sole Agreement, and shall supersede any prior Agreement
between the parties, for any new work or projects initiated after this Agreement is in effect.
3. THE AGREEMENT SUM. The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation and pursuant to the Price Methodology in Section 3.1.
3.1 Price Methodology:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized.
Only a single lump sum quote is required, no itemized breakdown for the lump sum quote will be
required for quoting or payment purposes. No time and material quotes will be accepted or
required for quoting or payment. Actual invoices for materials, subcontractors, mark-ups, etc. will
not be required for payment purposes, as the lump sum quote does not require a breakdown of
the quote or supporting documentation. Timesheets and/or timecards will not be accepted or
required for quoting or payment purposes to support labor hours, as they are not required for a
lump sum quote.
4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
Surety Construction Company
6640 Willow Park Drive, Suite B
Naples, FL 34109
Telephone: 239-992-6030
Fax: 239-992-7977
cfloyd(csuretvconst.com
Attention: Terry Kelly, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page -3-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1372-
6/14/2016 16.E.4.
Collier County Government Complex
Procurement Services Division
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Director, Procurement Services Division
Phone: 239-252-8407
Fax: 239-252-6480
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Owner will not be obligated to pay
for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and
other similar taxes associated with the Work or portions thereof, which are applicable during the
performance of the Work.
7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct
any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24)
hours after receiving notice of such violation, conduct, or practice, such suspension to continue
until the violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION. With respect to this Agreement, should the Contractor be found to have failed to
perform Contractor services in a manner satisfactory to the County and requirements of this
Agreement, the County may terminate said Agreement for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall
be sole judge of non-performance. With respect to a particular Project, termination shall be
governed by the terms of the Purchase Order.
9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
Page -4-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page -1373-
6/14/2016 16.E.4.
10. INSURANCE. The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of$1,000,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that Contractor is required to meet. The same Contractor shall provide County with
certificates of insurance meeting the required insurance provisions.
11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and
paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of
this Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified party or
person described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of a
claim by any party and written notice of such claim being provided to Contractor. Contractor's
obligation to indemnify and defend under this Article 11 will survive the expiration or earlier
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by
the applicable statute of limitations.
Page -5-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1374-
6/14/2016 16.E.4.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be
required to provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment
Bond prior to commencing performance, for the full amount of the Work, which shall act
as a security guaranteeing the performance of the Contractor's work and the payment
by the Contractor to any other party (ies) providing labor and/or materials in connection
with each construction or renovation project performed by the Contractor. The bonds
shall be furnished using the forms prescribed in Exhibit"A".
C. All performance security shall be continued for a six (6) month period beyond the final
completion of the project.
D. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5)
calendar days thereafter, substitute another bond and surety, both of which shall be
subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit "C."
14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any
payments otherwise due Contractor under this Agreement or any other Agreement between
Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it
from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of
the Work by the Contractor; or (g) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other Agreement between
Contractor and Owner.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from
specifications shall be approved in writing by Owner in advance.
01)
Page -6-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1375-
6/14/2016 16.E.4.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit a lump sum quote of any cost or time increases or savings it foresees as a result
of the change. If accepted by Owner, the change shall be considered a lump sum change
order quote and follow Section 3.1 of this Agreement. Except in an emergency endangering life
or property, or as expressly set forth herein, no addition or changes to the Work shall be made
except upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of Owner is
authorized to direct any extra or changed work orally. Any modifications to this Agreement
shall be in compliance with the County's Procurement Ordinance and Procurement Procedures
in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an Agreement is reached between Contractor and Owner concerning
the requested changes. Contractor shall promptly perform changes authorized by duly
executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the
Change Order in the manner as Owner and Contractor shall mutually agree.
18. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this
contract in accordance with the Procurement Ordinance, as amended, and Procurement
Procedures and Section 3.1 of this Agreement.
Page -7-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1376-
6/14/2016 16.E.4.
19. COMPLIANCE WITH LAWS. The Contractor agrees to comply, at its own expense, with all
federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements
applicable to the Project, including but not limited to those dealing with taxation, workers'
compensation, equal employment and safety (including, but not limited to, the Trench Safety
Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including
specifically those contractual requirements in F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION
OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT
THE CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
The Contractor must specifically comply with the Florida Public Records Law:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public
agency with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the Contractor
does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records required by
the public agency to perform the service. If the Contractor transfers all public records to
the public agency upon completion of the contract, the Contractor shall destroy any
duplicate public records that are exempt or confidential and exempt from public records
disclosure requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the public
agency, upon request from the public agency's custodian of public records, in a format
that is compatible with the information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to
unilaterally terminate this Agreement immediately.
20. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work. At the completion of the Work, Contractor shall
remove all debris, rubbish and waste materials from and about the Project site, as well as all
tools, appliances, construction equipment and machinery and surplus materials, and hall
leave the Project site clean and ready for occupancy by Owner.
Page -8-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page -1377-
6/14/2016 16.E.4.
21. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the
prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or
any part thereof, it shall require that its assignee be bound to it and to assume toward
Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
22. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any
of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's
Proposal, and/or the County's Board approved Executive Summary, this Agreement shall take
precedence.
23. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement
or repair. These warranties are in addition to those implied warranties to which Owner is
entitled as a matter of law.
24. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply
competent employees who are physically capable of performing their employment duties. The
County may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Collier County
projects is not in the best interest of the County.
25. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
26. PROTECTION OF WORK. 0
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Page -9-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1378-
6/14/2016 16.E.4.
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
27. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons
or the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the
occurrence of the emergency, if Contractor believes that any significant changes in the Work
or variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations. The Change Order shall be completed in
accordance with Section 3.1 of this Agreement.
If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
28. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner)
is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or
such designated portion) is substantially complete and request that Owner issue a Certificate
of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work (or designated portion thereof) to determine the status of
completion. If Owner does not consider the Work (or designated portion) substantially
complete, the Owner shall notify Contractor in writing giving the reasons therefor.
If Owner considers the Work (or designated portion) substantially complete, Owner shall
prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall
fix the date of Substantial Completion for the entire Work (or designated portion thereof) and
include a tentative punchlist of items to be completed or corrected by Contractor before final
payment.
Owner shall have the right to exclude Contractor from the Work and Project site (or designated
portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance
with the Contract Documents and is ready for final inspection and acceptance, Owner will
Page -10- 0
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1379-
6/14/2016 16.E.4.
make such inspection and, if Owner finds the Work acceptable and fully performed under the
Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit F,
recommending that on the basis of Owner's observations and inspections, and the
Contractor's certification that the Work has been completed in accordance with the terms and
conditions of the Contract Documents, that the entire balance found to be due Contractor is
due and payable. Final payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit"B."
(2) Consent of Surety (if applicable) to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to
the acceptability of the Work. Unless and until the Owner is completely satisfied, the final
payment shall not become due and payable.
29. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for
Quotation. The date of substantial completion of the Work (or designated portions thereof) is
the date certified by the Owner when construction is sufficiently complete, in accordance with
the Contract Documents, so Owner can occupy or utilize the Work (or designated portions
thereof) for the use for which it is intended. The Work shall reach final completion and be
ready for final acceptance by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete
the Work within the specified time period, Owner shall be entitled to assess as liquidated
damages, but not as a penalty, the amount specified in the Contract Documents, Summary of
Work, or Request for Quotation for each calendar day thereafter until substantial completion is
achieved.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby
expressly waives and relinquishes any right which it may have to seek characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if Contractor
fails to substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
0
Page -11-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1380-
6/14/2016 16.E4.
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
30. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the
County by the Facilities Management Division.
31. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set
out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP No. 16-6618, any
addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any
related plans or specifications for any such Quotations or Work Orders.
32. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall
offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value
to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County
Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a.
Prohibition by the individual, firm, and/or any employee of the firm from contact with County
staff for a specified period of time; b. Prohibition by the individual and/or firm from doing
business with the County for a specified period of time, including but not limited to: submitting
bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual
and/or firm for cause.
33. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
34. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. If
these costs are applicable, the costs will be included in the lump sum total and follow Section
3.1 of this Agreement.
35. IMMIGRATION LAW COMPLIANCE. By executing and entering into this Agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure
by the Contractor to comply with the laws referenced herein shall constitute a breach of this
Agreement and the County shall have the discretion to unilaterally terminate this Agreement
immediately.
36. VENUE. Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
37. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages
and agrees to the successful proposer extending the pricing, terms and conditions of this
solicitation or resultant Agreement to other governmental entities at the discretion of the
successful proposer.
Page -12-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1381-
6/14/2016 16.E.4.
38. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or
otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall
remain in effect.
39. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as
amended. Background checks are valid for five (5) years and the Contractor shall be
responsible for all associated costs. If required, Contractor shall be responsible for the costs of
providing background checks by the Collier County Facilities Management Division for all
employees that shall provide services to the County under this Agreement. This may include,
but not be limited to, checking federal, state and local law enforcement records, including a
state and FBI fingerprint check, credit reports, education, residence and employment
verifications and other related records. Contractor shall be required to maintain records on
each employee and make them available to the County for at least four (4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check
is valid, as discussed below. All technicians shall have on their shirts the name of the
contractor's business.
The Contractor shall immediately notify the Collier County Facilities Management Division via
e-mail (DL-FMOPSc colliergov.net) whenever an employee assigned to Collier County
separates from their employment. This notification is critical to ensure the continued security of
Collier County facilities and systems. Failure to notify within four (4) hours of separation may
result in a deduction of$500 per incident.
40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by
representatives of Contractor with full decision-making authority and by County's staff person
who would make the presentation of any settlement reached during negotiations to County for
approval. Failing resolution, and prior to the commencement of depositions in any litigation
between the parties arising out of this Agreement, the parties shall attempt to resolve the
dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State
of Florida. The mediation shall be attended by representatives of Contractor with full decision-
making authority and by County's staff person who would make the presentation of any
settlement reached at mediation to County's board for approval. Should either party fail to
submit to mediation as required hereunder, the other party may obtain a court order requiring
mediation under section 44.102, Fla. Stat.
41. SAFETY. All contractors and subcontractors performing service for Collier County are
required and shall comply with all Occupational Safety and Health Administration (OSHA),
State and County Safety and Occupational Health Standards and any other applicable rules
and regulations. Also all Contractors and subcontractors shall be responsible for the safety of
their employees and any unsafe acts or conditions that may cause injury or damage to any
persons or property within and around the work site.
Page -13-
CO
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1382-
6/14/2016 16.E.4.
Collier County Government has authorized the Occupational Safety and Health Administration
(OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of
inspection of any Contractor's work operations. This provision is non-negotiable by any
department/division and/or Contractor. All applicable OSHA inspection criteria apply as well
as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow
OSHA onto a project that is being performed on Collier County Property. Collier County, as the
owner of the property where the project is taking place shall be the only entity allowed to
refuse access to the project. However, this decision shall only be made by Collier County's
Risk Management Division Safety Manager and/or Safety Engineer.
***************************Remainder of page intentionally left blank*******************************
Page -14-
0
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1383-
I 6/14/2016 16.E.4.
I
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
BOARD OF COUNTY COMMISSIONERS
ATTEST: COLLIER COUNTY, FLORIDA
Dwight E. Brock, Clerk of Courts
By: By:
Donna Fiala, Chairman
Dated:
(Seal)
Surety Construction Company
By:
First Witness Signature
Print Name and Title Print Name and Title
Second Witness
Print Name and Title
Approved -'s t• '•r4. and legality:
-44 i i
ice , ..
Jeffrey A. -tz :!,w, County Attorney
0
Page -15-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1384-
6/14/2016 16.E.4.
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That , as
Principal, and , as Surety, located at
(Business Address) are held and firmly bound
to as Oblige in the sum of
($ ) for the payment whereof we bind ourselves, our heirs, executors, personal
representatives, successors and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of , 20,,
with Oblige for
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of under-signed representative, pursuant to authority of its governing
body.
0
Page -16-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1385-
6/14/2016 16.E4.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of 20_, by
as of , a
corporation, on behalf of the corporation. He/she is personally known to me OR has produced
as identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No,:
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
0
Page -17-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1386-
6/14/2016 16.E.4.
As Attorney in Fact
Witnesses (Attach Power of Attorney)
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20_, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(AFFIX OFFICIAL SEAL) (Legibly Printed)
Notary Public, State of
Commission No.:
Page -18-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1387-
6/14/2016 16.E.4.
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address) are held and firmly bound to
{ , as Oblige in the sum of
11 ($ ) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns,jointly and severally.
{ WHEREAS, Principal has entered into a contract dated as of the day of
20_, with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
0
Page -19-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1388-
6/14/2016 16.E.4.
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
201 , by , as of
a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(AFFIX OFFICIAL SEAL) (Legibly Printed)
Notary Public, State of
Commission No.:
Page -20-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1389-
6/14/2016 16.E.4.
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of , 20 , by_
, as of
, Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -21-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1390-
x.
6/14/2016 16.E.4.
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and it's
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and Owner, dated
20 for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted against the Owner arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS: President
DATE:
Witnesses
STATE OF [Corporate Seal]
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by , as of
a corporation, on behalf of the corporation. He/she is
personally known to me or has produced as
identification and did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commissioner No.:
Page -22-
Agreement#16-6618"General ContractorS- • -s"
Surety Construction Company
Packet Page-1391-
6/14/2016 16.E.4.
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager) Bid No. 16-6618
(County Department) Project No.
Collier County Board of County Commissioners(the OWNER)or
Collier County Water-Sewer District(the OWNER) Application Date
FROM: (Contractor's Representative) Payment Application No.
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE: (Project
Name)
Original Contract Time: Original Contract Amount: $
Revised Contract Time: Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
Retainage @ 10% thru[insert date] $ and stored to Date $
Retainage @ _%after [insert date] $ Less previous payment(s) $
Percent Work completed to Date: % AMOUNT DUE THIS
Percent Contract Time completed to Date % APPLICATION: $
Liquidated Damages to be Accrued $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER). The value of such
materials and equipment is not relevant and proof of value/cost will not be required; (3) all amounts have been paid for
work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and
CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the
revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
(Signature)
DATE:
(Type Name&Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional: (DP's Name)
(Signature)DATE:
(Type Name&Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager: (Signature) DATE:
(Type Name and Title)
Page -23- 0
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1392-
a
6/14/2016 16.E.4.
EXHIBIT D
CHANGE ORDER
❑Contract Modification ❑Work Order Modification
❑Amendment
Contract#: Change#: Purchase Order#: Project#:
Contractor/Firm Name: Project Name:
Project Manager Name: Department:
Original Contract/Work Order Amount !Original BCC Approval Date; Agenda Item#!
Current BCC Approved Amount
Last BCC Approval Dated Agenda Item
Current Contract/Work Order Amountr"
SAP Contract Expiration Date(Master)
Dollar Amount of this Chane
... ._.,9 #DIV/Oi Total Change from Original Amount
Revised Contract/Work Order Total $ 0.00 #DIV/0i Change from Current BCC Approved Amount
Cumulative Changes $ 0.00 #DIV/0! (Change from Current Amount
• Completion Date Description of the.Task(s)change,and Rationale for the Change '.
Notice to Proceed I I Original I (Approved KI Date
Date ompletion Date _...J es this change)
#of Days Added Select Tasks 0 Add new task(s) 0 Delete task(s) 0 Change task(s) 0 Other(see
below)
Provide a response to the following: 1.)detailed and specific explanation/rationale of the requested change(s)to the task(s)
and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.)
describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if
needed.
Prepared by: Date:
(Project Manager Name and Division)
Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the
same terms and conditions as contained in the contract /work order indicated above, as fully as if the same were stated in this
acceptance. The adjustment, if any, to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/
Vendor/Consultant/Design Professional arising out of or related to the change set forth herein, including claims for impact and delay
costs.
Accepted by: Date:
(Contractor/Vendor/Consultant/Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Procurement Professional
Page -24- 0
Agreement#16-6618"General Contractor Services
Surety Construction Company
Packet Page-1393-
6/14/2016 16.E.4.
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -25-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1394-
_
6/14/2016 16.E.4.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
, 20_
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
, 20
OWNER
By:
Type Name and Title
Page -26-
0
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page -1395-
{ 6/14/2016 16.E.4.
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page -27- 0
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1396-
6/14/2016 16.E.4.
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on ,� —
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
Page -28-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page-1397-
i
6/14/2016 16.E.4.
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
Page -29-
Agreement#16-6618"General Contractor Services"
Surety Construction Company
Packet Page -1398-
6/14/2016 16.E.4.
II'
AGREEMENT16-6618
for
General Contractor Services
THIS AGREEMENT is made and entered into this day of , 2016, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or"Owner") and Bradanna, Inc., authorized to
do business in the State of Florida, whose business address is 125 Airport Road, North, Suite 200,
Naples, Florida 34104 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. TERM AND COMMENCEMENT. The Agreement shall be for a two (2) year period, commencing
on date of award by the Collier County Board of County Commissioners, and terminating until
such time as all outstanding Work Orders issued prior to the expiration of the Agreement period
have been completed or terminated.
The County may, at its discretion and with the consent of the Contractor, renew the Agreement
under all of the terms and conditions contained in this Agreement for one (1) additional two (2)
year term. The County shall give the Contractor written notice of the County's intention to renew
the Agreement term not less than ten (10) days prior to the end of the Agreement term.
The County Manager, or his designee, may, at his discretion, extend the Agreement under all of
the terms and conditions contained in this Agreement for up to one hundred eighty (180) days.
The Contractor shall commence the Work upon issuance of a Work Order accompanied by a
Notice to Proceed.
2. STATEMENT OF WORK. The Board of County Commissioners deemed six (6) firms to be
qualified and awarded an Agreement to each firm. Each awardee will enter into an Agreement to
provide complete services for General Contractor Services on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP#16-6618 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement.
2.1 The execution of this Agreement shall not be a commitment to the Contractor that any Work
will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
procedure to obtain Work and all Work undertaken by Contractor for Owner pursuant to this
Agreement during the term and any extension of the term of this Agreement. Any County Agency
may utilize the services offered under this Agreement, provided sufficient funds are included in the
budget(s).
040
Page -1-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1399-
6/14/2016 16.E.4.
2.2 The procedure for obtaining Work under this Agreement is as follows:
For projects with a value up to three thousand ($3,000) dollars is as follows:
• County Staff will select one of the awarded Contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
•
For projects above three thousand ($3,000) and up to fifty thousand ($50,000) dollars is
as follows:
• A summary of work will be offered to all Contractors under contract. The Contractors will
respond by providing fixed price, lump sum quote following the price methodology in
Section 3.1 within seven (7) working days or as a time agreed to by the County's project
manager for non emergency work and within twenty-four (24) hours for emergency work
from the time of the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all Contractors under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages, if
required.
• The Contractors will respond by providing fixed price, lump sum quote following the price
methodology in Section 3.1 and the requisite quote information requested by the County's
project manager which may include Performance and Payment Bonds requirements,
within seven (7) working days or as a time agreed to by the County's project manager for
non emergency work and within twenty-four (24) hours for emergency work from the time
of the request. If required, the Project Manager shall attach the Bond paperwork to the
SAP requisition and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
Procedures for projects with a value of$250,000 and above are as follows:
• This Agreement is limited for work or projects with an estimated initial value up to
$250,000. This value may be increased after the award by Change Orders for
unanticipated difficulties, work or costs, as set forth in the County's Procurement
Ordinance. Work or projects with an estimated initial value in excess of $250,000 are
outside of the scope of this Agreement, will be competitively bid in accordance with the
County's Procurement Ordinance and will require Board of County Commissioners
approval. 0.0
Page -2-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1400-
6/14/2016 16.E.4.
For each awarded Project, as part of the Contract Documents or in each Summary of Work or
Request for Quotation, the Owner reserves the right to specify: the period of completion; collection
of liquidated damages in the event of late completion.
2.3 This Agreement contains the entire understanding between the parties and any modifications
to this Agreement shall be mutually agreed upon in writing by the Contractor and the County, in
compliance with the Procurement Ordinance, as amended and Procurement Procedures in effect
at the time such services are authorized.
2.4 This Agreement shall be the sole Agreement, and shall supersede any prior Agreement
between the parties, for any new work or projects initiated after this Agreement is in effect.
3. THE AGREEMENT SUM. The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation and pursuant to the Price Methodology in Section 3.1.
3.1 Price Methodology:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized.
Only a single lump sum quote is required, no itemized breakdown for the lump sum quote will be
required for quoting or payment purposes. No time and material quotes will be accepted or
required for quoting or payment. Actual invoices for materials, subcontractors, mark-ups, etc. will
not be required for payment purposes, as the lump sum quote does not require a breakdown of
the quote or supporting documentation. Timesheets and/or timecards will not be accepted or
required for quoting or payment purposes to support labor hours, as they are not required for a
lump sum quote.
4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
Bradanna, Inc.
125 Airport Road, North, Suite 200
Naples, FL 34104
Telephone: 239-455-8891
Fax: 239-417-1461
ioeAbradanna.com
Attention: Joe Steinmann, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page -3-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1401-
6/14/2016 16.E.4.
Collier County Government Complex
Procurement Services Division
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Director, Procurement Services Division
Phone: 239-252-8407
Fax: 239-252-6480
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Owner will not be obligated to pay
for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and
other similar taxes associated with the Work or portions thereof, which are applicable during the
performance of the Work.
7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct
any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24)
hours after receiving notice of such violation, conduct, or practice, such suspension to continue
until the violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION. With respect to this Agreement, should the Contractor be found to have failed to
perform Contractor services in a manner satisfactory to the County and requirements of this
Agreement, the County may terminate said Agreement for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall
be sole judge of non-performance. With respect to a particular Project, termination shall be
governed by the terms of the Purchase Order.
9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
Page -4-
Agreement#16-6618"General Contra or Services"
Bradanna,Inc.
Packet Page-1402-
6/14/2016 16.E.4.
10. INSURANCE. The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of$1,000,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that Contractor is required to meet. The same Contractor shall provide County with
certificates of insurance meeting the required insurance provisions.
11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and
paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of
this Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified party or
person described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of a
claim by any party and written notice of such claim being provided to Contractor. Contractor's
obligation to indemnify and defend under this Article 11 will survive the expiration or earlier
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by
the applicable statute of limitations.
o`4 13
Page -5-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1403-
6/14/2016 16.E.4.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be
required to provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment
Bond prior to commencing performance, for the full amount of the Work, which shall act
as a security guaranteeing the performance of the Contractor's work and the payment
by the Contractor to any other party (ies) providing labor and/or materials in connection
with each construction or renovation project performed by the Contractor. The bonds
shall be furnished using the forms prescribed in Exhibit"A".
C. AU performance security shall be continued for a six (6) month period beyond the final
completion of the project.
D. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5)
calendar days thereafter, substitute another bond and surety, both of which shall be
subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit "C."
14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any
payments otherwise due Contractor under this Agreement or any other Agreement between
Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it
from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of
the Work by the Contractor; or (g) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other Agreement between
Contractor and Owner.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from
specifications shall be approved in writing by Owner in advance.
0
Page -6-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1404-
6/14/2016 16.E.4.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit a lump sum quote of any cost or time increases or savings it foresees as a result
of the change. If accepted by Owner, the change shall be considered a lump sum change
order quote and follow Section 3.1 of this Agreement. Except in an emergency endangering life
or property, or as expressly set forth herein, no addition or changes to the Work shall be made
except upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of Owner is
authorized to direct any extra or changed work orally. Any modifications to this Agreement
shall be in compliance with the County's Procurement Ordinance and Procurement Procedures
in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an Agreement is reached between Contractor and Owner concerning
the requested changes. Contractor shall promptly perform changes authorized by duly
executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the
Change Order in the manner as Owner and Contractor shall mutually agree.
18. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this
contract in accordance with the Procurement Ordinance, as amended, and Procurement
Procedures and Section 3.1 of this Agreement.
Page -7-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1405-
6/14/2016 16.E.4.
19. COMPLIANCE WITH LAWS. The Contractor agrees to comply, at its own expense, with all
federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements
applicable to the Project, including but not limited to those dealing with taxation, workers'
compensation, equal employment and safety (including, but not limited to, the Trench Safety
Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including
specifically those contractual requirements in F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION
OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT
THE CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
The Contractor must specifically comply with the Florida Public Records Law:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public
agency with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the Contractor
does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records required by
the public agency to perform the service. If the Contractor transfers all public records to
the public agency upon completion of the contract, the Contractor shall destroy any
duplicate public records that are exempt or confidential and exempt from public records
disclosure requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the public
agency, upon request from the public agency's custodian of public records, in a format
that is compatible with the information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to
unilaterally terminate this Agreement immediately.
20. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work. At the completion of the Work, Contractor shall
remove all debris, rubbish and waste materials from and about the Project site, as well as all
tools, appliances, construction equipment and machinery and surplus materials, and shall
leave the Project site clean and ready for occupancy by Owner.
Page -8-
Adreement#16-6618"Ge contractor Services"
Bradanna,Inc.
Packet Page -1406-
6/14/2016 16.E.4.
21. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the
prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or
any part thereof, it shall require that its assignee be bound to it and to assume toward
Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
22. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any
of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's
Proposal, and/or the County's Board approved Executive Summary, this Agreement shall take
precedence.
23. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement
or repair. These warranties are in addition to those implied warranties to which Owner is
entitled as a matter of law.
24. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply
competent employees who are physically capable of performing their employment duties. The
County may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Collier County
projects is not in the best interest of the County.
25. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
26. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Page -9-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1407- 04(3
6/14/2016 16.E.4.
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
27. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons
or the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the
occurrence of the emergency, if Contractor believes that any significant changes in the Work
or variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations. The Change Order shall be completed in
accordance with Section 3.1 of this Agreement.
If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
28. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner)
is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or
such designated portion) is substantially complete and request that Owner issue a Certificate
of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work (or designated portion thereof) to determine the status of
completion. If Owner does not consider the Work (or designated portion) substantially
complete, the Owner shall notify Contractor in writing giving the reasons therefor.
If Owner considers the Work (or designated portion) substantially complete, Owner shall
prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall
fix the date of Substantial Completion for the entire Work (or designated portion thereof) and
include a tentative punchlist of items to be completed or corrected by Contractor before final
payment.
Owner shall have the right to exclude Contractor from the Work and Project site (or designated
portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance
with the Contract Documents and is ready for final inspection and acceptance, Owner will
Page -10-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1408-
6/14/2016 16.E.4.
make such inspection and, if Owner finds the Work acceptable and fully performed under the
Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit F,
recommending that on the basis of Owner's observations and inspections, and the
Contractor's certification that the Work has been completed in accordance with the terms and
conditions of the Contract Documents, that the entire balance found to be due Contractor is
due and payable. Final payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit "B."
(2) Consent of Surety (if applicable) to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to
the acceptability of the Work. Unless and until the Owner is completely satisfied, the final
payment shall not become due and payable.
29. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for
Quotation. The date of substantial completion of the Work (or designated portions thereof) is
the date certified by the Owner when construction is sufficiently complete, in accordance with
the Contract Documents, so Owner can occupy or utilize the Work (or designated portions
thereof) for the use for which it is intended. The Work shall reach final completion and be
ready for final acceptance by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete
the Work within the specified time period, Owner shall be entitled to assess as liquidated
damages, but not as a penalty, the amount specified in the Contract Documents, Summary of
Work, or Request for Quotation for each calendar day thereafter until substantial completion is
achieved.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby
expressly waives and relinquishes any right which it may have to seek characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if Contractor
fails to substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
Page -11-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1409- 04)
6/14/2016 16.E.4.
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
30. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the
County by the Facilities Management Division.
31. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set
out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP No. 16-6618, any
addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any
related plans or specifications for any such Quotations or Work Orders.
32. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall
offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value
to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County
Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a.
Prohibition by the individual, firm, and/or any employee of the firm from contact with County
staff for a specified period of time; b. Prohibition by the individual and/or firm from doing
business with the County for a specified period of time, including but not limited to: submitting
bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual
and/or firm for cause.
33. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
34. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. If
these costs are applicable, the costs will be included in the lump sum total and follow Section
3.1 of this Agreement.
n Agreement,35. IMMIGRATION LAW COMPLIANCE. By executing and entering into this the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure
by the Contractor to comply with the laws referenced herein shall constitute a breach of this
Agreement and the County shall have the discretion to unilaterally terminate this Agreement
immediately.
36. VENUE. Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
37. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages
and agrees to the successful proposer extending the pricing, terms and conditions of this
solicitation or resultant Agreement to other governmental entities at the discretion of the
successful proposer.
Page -12-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1410-
6/14/2016 16.E.4.
38. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or
otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall
remain in effect.
39. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as
amended. Background checks are valid for five (5) years and the Contractor shall be
responsible for all associated costs. If required, Contractor shall be responsible for the costs of
providing background checks by the Collier County Facilities Management Division for all
employees that shall provide services to the County under this Agreement. This may include,
but not be limited to, checking federal, state and local law enforcement records, including a
state and FBI fingerprint check, credit reports, education, residence and employment
verifications and other related records. Contractor shall be required to maintain records on
each employee and make them available to the County for at least four (4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check
is valid, as discussed below. All technicians shall have on their shirts the name of the
contractor's business.
The Contractor shall immediately notify the Collier County Facilities Management Division via
e-mail (DL-FMOPS( colliergov.net) whenever an employee assigned to Collier County
separates from their employment. This notification is critical to ensure the continued security of
Collier County facilities and systems. Failure to notify within four (4) hours of separation may
result in a deduction of$500 per incident.
40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by
representatives of Contractor with full decision-making authority and by County's staff person
who would make the presentation of any settlement reached during negotiations to County for
approval. Failing resolution, and prior to the commencement of depositions in any litigation
between the parties arising out of this Agreement, the parties shall attempt to resolve the
dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State
of Florida. The mediation shall be attended by representatives of Contractor with full decision-
making authority and by County's staff person who would make the presentation of any
settlement reached at mediation to County's board for approval. Should either party fail to
submit to mediation as required hereunder, the other party may obtain a court order requiring
mediation under section 44.102, Fla. Stat.
41. SAFETY. All contractors and subcontractors performing service for Collier County are
required and shall comply with all Occupational Safety and Health Administration (OSHA),
State and County Safety and Occupational Health Standards and any other applicable rules
and regulations. Also all Contractors and subcontractors shall be responsible for the safety of
their employees and any unsafe acts or conditions that may cause injury or damage to any
persons or property within and around the work site.
Page -13-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1411-
6/14/2016 16.E.4.
Collier County Government has authorized the Occupational Safety and Health Administration
(OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of
inspection of any Contractor's work operations. This provision is non-negotiable by any
department/division and/or Contractor. All applicable OSHA inspection criteria apply as well
as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow
OSHA onto a project that is being performed on Collier County Property. Collier County, as the
owner of the property where the project is taking place shall be the only entity allowed to
refuse access to the project. However, this decision shall only be made by Collier County's
Risk Management Division Safety Manager and/or Safety Engineer.
***************************Remainder of page intentionally left blank*******************************
Page -14-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1412-
6/14/2016 16.E.4.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
BOARD OF COUNTY COMMISSIONERS
ATTEST: COLLIER COUNTY, FLORIDA
Dwight E. Brock, Clerk of Courts
By: By:
Donna Fiala, Chairman
Dated:
(Seal)
Bradanna, Inc.
By:
First Witness Signature
Print Name and Title Print Name and Title
Second Witness
Print Name and Title
Approve• as flirm and—legality:
l
Jeffrey A. la ow, County Attorney
Page -15-
Agreement#16-6618"General Contractor Services"
Bradanna, Inc.
Packet Page-1413-
e
6/14/2016 16.E.4.
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That , as
Principal, and , as Surety, located at
(Business Address) are held and firmly bound
to as Oblige in the sum of
($ ) for the payment whereof we bind ourselves, our heirs, executors, personal
representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of , 20_,
with Oblige for
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of under-signed representative, pursuant to authority of its governing
body.
0
Page -16-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1414-
6/14/2016 16.E4.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of 20 , by
, as of , a
corporation, on behalf of the corporation. He/she is personally known to me OR has produced
as identification and did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
Page -17-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1415- e
6/14/2016 16.E.4.
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -18-
Agreement#16-6618 j.keral Contractor Services"
Bradanna,Inc.
Packet Page-1416-
6/14/2016 16.E.4.
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address) are held and firmly bound to
, as Oblige in the sum of
($ ) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
20 , with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page -19-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1417-
6/14/2016 16.E.4.
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
201_, by , as of
, a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -20-
Agreement#16-6618"Ge Contractor Services"
• Bradanna,Inc.
®
Packet Page-1418-
ATTEST: SURETY: 6/14/2016 16.E.4.
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of , 20 , by_
, as of
, Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -21-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1419-
6/14/2016 16.E.4.
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and it's
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and Owner, dated
20 for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted against the Owner arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS: President
DATE:
Witnesses
[Corporate Seal]
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by , as of
, a corporation, on behalf of the corporation. He/she is
personally known to me or has produced as
identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commissioner No.:
Page -22-
Agreement#16-6618"G-,eral Contractor Services"
Bradanna,Inc.
Packet Page -1420-
•
6/14/2016 16.E.4.
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager) Bid No. 16-6618
(County Department) Project No.
Collier County Board of County Commissioners(the OWNER)or
Collier County Water-Sewer District(the OWNER) Application Date
FROM: (Contractor's Representative) Payment Application No.
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE: (Project
Name)
Original Contract Time: Original Contract Amount: $
Revised Contract Time: Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
Retainage @ 10% thru[insert date] $ and stored to Date $
Retainage @ _% after [insert date] $ Less previous payment(s) $
Percent Work completed to Date: % AMOUNT DUE THIS
Percent Contract Time completed to Date % APPLICATION: $
Liquidated Damages to be Accrued $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER). The value of such
materials and equipment is not relevant and proof of value/cost will not be required; (3) all amounts have been paid for
work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and
CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the
revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
(Signature)
DATE:
(Type Name&Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional : (DP's Name)
(Signature) DATE:
(Type Name&Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager: (Signature) DATE:
(Type Name and Title)
Page -23-
Agreement#16-6618"General Contractor Services"
Bradanna, Inc.
Packet Page-1421-
6/14/2016 16.E.4.
EXHIBIT D
CHANGE ORDER
❑Contract Modification 0 Work Order Modification 0 Amendment
Contract#: Change#: Purchase Order#: Project#:
Contractor/Firm Name: Project Name:
Project Manager Name: Department:
Original Contract/Work Order Amount Original BCC Approval Date; Agenda Item #:
Current BCC Approved Amount Last BCC Approval Date, Agenda Item # {
Current Contract/Work Order Amount `SAP Contract Expiration Date(Master)
Dollar Amount of this Change #DIV/0' Total Change from Original Amount
Revised Contract/Work Order Total $ 0.00 #DIV/0! ,Change from Current BCC Approved Amount
Cumulative Changes $ 0.00 #DIV/0! :Change from Current Amount
Completion Date,Description of the Tasks)Change;and Rabonaleifor the ettange45-
Notice to Proceed Original Approved id Date
Date .ompletion Date es this change)
#of Days Added Select Tasks 0 Add new task(s) 0 Delete task(s) 0 Change task(s) 0 Other(see
below)
Provide a response to the following: 1.) detailed and specific explanation/rationale of the requested change(s)to the task(s)
and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.)
describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if
needed.
Prepared by: Date:
(Project Manager Name and Division)
Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the
same terms and conditions as contained in the contract / work order indicated above, as fully as if the same were stated in this
acceptance. The adjustment, if any,to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/
Vendor/Consultant/Design Professional arising out of or related to the change set forth herein,including claims for impact and delay
costs.
Accepted by: Date:
(Contractor/Vendor/Consultant/Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Procurement Professional
Page -24-
Agreement#16-6618"General Contractor Services"
Packet Page-1422- Bradanna,Inc.
6/14/2016 16.E.4.
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -25-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1423-
6/14/2016 16.E.4.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
, 20_
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
, 20_
OWNER
By:
Type Name and Title
Page -26-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page -1424-
6/14/2016 16.E.4.
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page -27-
Agreement#16-6618"General Contractor Services"
Bradanna,Inc.
Packet Page-1425-
6/14/2016 16.E.4.
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
Page -28-
Aareement#16-6618"General Contractor Services"
O Bradanna, Inc.
Packet Page -1426- CZ
6/14/2016 16.E.4.
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
Page -29-
Agreement#16-6618"General • tractor Services"
d Bradanna,Inc.
Packet Page-1427- U�
6/14/2016 16.E.4.
AGREEMENT 16-6618
for
General Contractor Services
THIS AGREEMENT is made and entered into this day of , 2016, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner") and Compass Construction, Inc.,
authorized to do business in the State of Florida, whose business address is 824 Lafayette Street,
Cape Coral, Florida 33904 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. TERM AND COMMENCEMENT. The Agreement shall be for a two (2) year period, commencing
on date of award by the Collier County Board of County Commissioners, and terminating until
such time as all outstanding Work Orders issued prior to the expiration of the Agreement period
have been completed or terminated.
The County may, at its discretion and with the consent of the Contractor, renew the Agreement
under all of the terms and conditions contained in this Agreement for one (1) additional two (2)
year term. The County shall give the Contractor written notice of the County's intention to renew
the Agreement term not less than ten (10) days prior to the end of the Agreement term.
The County Manager, or his designee, may, at his discretion, extend the Agreement under all of
the terms and conditions contained in this Agreement for up to one hundred eighty (180) days.
The Contractor shall commence the Work upon issuance of a Work Order accompanied by a
Notice to Proceed.
2. STATEMENT OF WORK. The Board of County Commissioners deemed six (6) firms to be
qualified and awarded an Agreement to each firm. Each awardee will enter into an Agreement to
provide complete services for General Contractor Services on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP#16-6618 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement.
2.1 The execution of this Agreement shall not be a commitment to the Contractor that any Work
will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
procedure to obtain Work and all Work undertaken by Contractor for Owner pursuant to this
Agreement during the term and any extension of the term of this Agreement. Any County Agency
may utilize the services offered under this Agreement, provided sufficient funds are included in the
budget(s).
0
Page-1-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1428-
6/14/2016 16.E.4.
2.2 The procedure for obtaining Work under this Agreement is as follows:
For projects with a value up to three thousand ($3,000) dollars is as follows:
• County Staff will select one of the awarded Contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
For projects above three thousand ($3,000) and up to fifty thousand ($50,000) dollars is
as follows:
• A summary of work will be offered to all Contractors under contract. The Contractors will
respond by providing fixed price, lump sum quote following the price methodology in
Section 3.1 within seven (7) working days or as a time agreed to by the County's project
manager for non emergency work and within twenty-four (24) hours for emergency work
from the time of the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all Contractors under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages, if
required.
• The Contractors will respond by providing fixed price, lump sum quote following the price
methodology in Section 3.1 and the requisite quote information requested by the County's
project manager which may include Performance and Payment Bonds requirements,
within seven (7) working days or as a time agreed to by the County's project manager for
non emergency work and within twenty-four (24) hours for emergency work from the time
of the request. If required, the Project Manager shall attach the Bond paperwork to the
SAP requisition and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
Procedures for projects with a value of$250,000 and above are as follows:
• This Agreement is limited for work or projects with an estimated initial value up to
$250,000. This value may be increased after the award by Change Orders for
unanticipated difficulties, work or costs, as set forth in the County's Procurement
Ordinance. Work or projects with an estimated initial value in excess of $250,000 are
outside of the scope of this Agreement, will be competitively bid in accordance with the
County's Procurement Ordinance and will require Board of County Commissioners
approval.
Page -2-
C
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1429-
6/14/2016 16.E.4.
For each awarded Project, as part of the Contract Documents or in each Summary of Work or
Request for Quotation, the Owner reserves the right to specify: the period of completion; collection
of liquidated damages in the event of late completion.
2.3 This Agreement contains the entire understanding between the parties and any modifications
to this Agreement shall be mutually agreed upon in writing by the Contractor and the County, in
compliance with the Procurement Ordinance, as amended and Procurement Procedures in effect
at the time such services are authorized.
2.4 This Agreement shall be the sole Agreement, and shall supersede any prior Agreement
between the parties, for any new work or projects initiated after this Agreement is in effect.
3. THE AGREEMENT SUM. The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation and pursuant to the Price Methodology in Section 3.1.
3.1 Price Methodolow:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized.
Only a single lump sum quote is required, no itemized breakdown for the lump sum quote will be
required for quoting or payment purposes. No time and material quotes will be accepted or
required for quoting or payment. Actual invoices for materials, subcontractors, mark-ups, etc. will
not be required for payment purposes, as the lump sum quote does not require a breakdown of
the quote or supporting documentation. Timesheets and/or timecards will not be accepted or
required for quoting or payment purposes to support labor hours, as they are not required for a
lump sum quote.
4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
Compass Construction, Inc.
824 Lafayette Street
Cape Coral, Florida 33904
Telephone: 239-542-7118
Fax: 239-542-8648
doliver(a compassconstruction.com
Attention: Doug Oliver, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page -3-
Agreement#16-6618"General Contractor Services
Compass Construction,Inc.
Packet Page -1430-
1
6/14/2016 16.E.4.
Collier County Government Complex
Procurement Services Division
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Director, Procurement Services Division
Phone: 239-252-8407
Fax: 239-252-6480
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Owner will not be obligated to pay
for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and
other similar taxes associated with the Work or portions thereof, which are applicable during the
performance of the Work.
7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct
any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24)
hours after receiving notice of such violation, conduct, or practice, such suspension to continue
until the violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION. With respect to this Agreement, should the Contractor be found to have failed to
perform Contractor services in a manner satisfactory to the County and requirements of this
Agreement, the County may terminate said Agreement for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall
be sole judge of non-performance. With respect to a particular Project, termination shall be
governed by the terms of the Purchase Order.
WIN
Page -4-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1431-
6/14/2016 16.E.4.
9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
10. INSURANCE. The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of$1,000,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that Contractor is required to meet. The same Contractor shall provide County with
certificates of insurance meeting the required insurance provisions.
11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and
paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of
this Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified party or
person described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of a
claim by any party and written notice of such claim being provided to Contractor. Contractor's
obligation to indemnify and defend under this Article 11 will survive the expiration or earlier
Page -5-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1432-
6/14/2016 16.E.4.
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by
the applicable statute of limitations.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be
required to provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment
Bond prior to commencing performance, for the full amount of the Work, which shall act
as a security guaranteeing the performance of the Contractor's work and the payment
by the Contractor to any other party (ies) providing labor and/or materials in connection
with each construction or renovation project performed by the Contractor. The bonds
shall be furnished using the forms prescribed in Exhibit"A".
C. All performance security shall be continued for a six (6) month period beyond the final
completion of the project.
D. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5)
calendar days thereafter, substitute another bond and surety, both of which shall be
subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit "C."
14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any
payments otherwise due Contractor under this Agreement or any other Agreement between
Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it
from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of
the Work by the Contractor; or(g) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other Agreement between
Contractor and Owner.
Page -6-
GN°
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1433-
6/14/2016 16.E.4.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from
specifications shall be approved in writing by Owner in advance.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit a lump sum quote of any cost or time increases or savings it foresees as a result
of the change. If accepted by Owner, the change shall be considered a lump sum change
order quote and follow Section 3.1 of this Agreement. Except in an emergency endangering life
or property, or as expressly set forth herein, no addition or changes to the Work shall be made
except upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of Owner is
authorized to direct any extra or changed work orally. Any modifications to this Agreement
shall be in compliance with the County's Procurement Ordinance and Procurement Procedures
in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an Agreement is reached between Contractor and Owner concerning
the requested changes. Contractor shall promptly perform changes authorized by duly
executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the
Change Order in the manner as Owner and Contractor shall mutually agree. SAO
Page -7-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1434-
6/14/2016 16.E.4.
18. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this
contract in accordance with the Procurement Ordinance, as amended, and Procurement
Procedures and Section 3.1 of this Agreement.
19. COMPLIANCE WITH LAWS. The Contractor agrees to comply, at its own expense, with all
federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements
applicable to the Project, including but not limited to those dealing with taxation, workers'
compensation, equal employment and safety (including, but not limited to, the Trench Safety
Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including
specifically those contractual requirements in F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION
OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT
THE CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
The Contractor must specifically comply with the Florida Public Records Law:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public
agency with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the Contractor
does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records required by
the public agency to perform the service. If the Contractor transfers all public records to
the public agency upon completion of the contract, the Contractor shall destroy any
duplicate public records that are exempt or confidential and exempt from public records
disclosure requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the public
agency, upon request from the public agency's custodian of public records, in a format
that is compatible with the information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to
unilaterally terminate this Agreement immediately.
Page -8-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1435CID
-
6/14/2016 16.E.4.
20. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work. At the completion of the Work, Contractor shall
remove all debris, rubbish and waste materials from and about the Project site, as well as all
tools, appliances, construction equipment and machinery and surplus materials, and shall
leave the Project site clean and ready for occupancy by Owner.
21. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the
prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or
any part thereof, it shall require that its assignee be bound to it and to assume toward
Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
22. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any
of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's
Proposal, and/or the County's Board approved Executive Summary, this Agreement shall take
precedence.
23. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement
or repair. These warranties are in addition to those implied warranties to which Owner is
entitled as a matter of law.
24. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply
competent employees who are physically capable of performing their employment duties. The
County may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Collier County
projects is not in the best interest of the County.
25. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
Page -9-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1436-
6/14/2016 16.E.4.
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
26. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
27. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons
or the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the
occurrence of the emergency, if Contractor believes that any significant changes in the Work
or variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations. The Change Order shall be completed in
accordance with Section 3.1 of this Agreement.
If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
28. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner)
is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or
such designated portion) is substantially complete and request that Owner issue a Certificate
of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work (or designated portion thereof) to determine the status of
completion. If Owner does not consider the Work (or designated portion) substantially
complete, the Owner shall notify Contractor in writing giving the reasons therefor.
If Owner considers the Work (or designated portion) substantially complete, Owner shall
prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall
fix the date of Substantial Completion for the entire Work (or designated portion thereof) and
Page -10-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1437-
6/14/2016 16.E.4.
include a tentative punchlist of items to be completed or corrected by Contractor before final
payment.
Owner shall have the right to exclude Contractor from the Work and Project site (or designated
portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance
with the Contract Documents and is ready for final inspection and acceptance, Owner will
make such inspection and, if Owner finds the Work acceptable and fully performed under the
Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit F,
recommending that on the basis of Owner's observations and inspections, and the
Contractor's certification that the Work has been completed in accordance with the terms and
conditions of the Contract Documents, that the entire balance found to be due Contractor is
due and payable. Final payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit"B."
(2) Consent of Surety (if applicable) to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to
the acceptability of the Work. Unless and until the Owner is, completely satisfied, the final
payment shall not become due and payable.
29. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for
Quotation. The date of substantial completion of the Work (or designated portions thereof) is
the date certified by the Owner when construction is sufficiently complete, in accordance with
the Contract Documents, so Owner can occupy or utilize the Work (or designated portions
thereof) for the use for which it is intended. The Work shall reach final completion and be
ready for final acceptance by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete
the Work within the specified time period, Owner shall be entitled to assess as liquidated
damages, but not as a penalty, the amount specified in the Contract Documents, Summary of
Work, or Request for Quotation for each calendar day thereafter until substantial completion is
achieved.
Page -11-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1438-
6/14/2016 16.E.4.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby
expressly waives and relinquishes any right which it may have to seek characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if Contractor
fails to substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
30. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the
County by the Facilities Management Division.
31. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set
out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP No. 16-6618, any
addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any
related plans or specifications for any such Quotations or Work Orders.
32. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall
offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value
to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County
Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a.
Prohibition by the individual, firm, and/or any employee of the firm from contact with County
staff for a specified period of time; b. Prohibition by the individual and/or firm from doing
business with the County for a specified period of time, including but not limited to: submitting
bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual
and/or firm for cause.
33. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
34. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. If
these costs are applicable, the costs will be included in the lump sum total and follow Section
3.1 of this Agreement.
35. IMMIGRATION LAW COMPLIANCE. By executing and entering into this Agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure
by the Contractor to comply with the laws referenced herein shall constitute a breach of this
Page-12-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1439-
6/14/2016 16.E.4.
Agreement and the County shall have the discretion to unilaterally terminate this Agreement
immediately.
36. VENUE. Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
37. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages
and agrees to the successful proposer extending the pricing, terms and conditions of this
solicitation or resultant Agreement to other governmental entities at the discretion of the
successful proposer.
38. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or
otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall
remain in effect.
39. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as
amended. Background checks are valid for five (5) years and the Contractor shall be
responsible for all associated costs. If required, Contractor shall be responsible for the costs of
providing background checks by the Collier County Facilities Management Division for all
employees that shall provide services to the County under this Agreement. This may include,
but not be limited to, checking federal, state and local law enforcement records, including a
state and FBI fingerprint check, credit reports, education, residence and employment
verifications and other related records. Contractor shall be required to maintain records on
each employee and make them available to the County for at least four (4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check
is valid, as discussed below. All technicians shall have on their shirts the name of the
contractor's business.
The Contractor shall immediately notify the Collier County Facilities Management Division via
e-mail (DL-FMOPS@colliergov.net) whenever an employee assigned to Collier County
separates from their employment. This notification is critical to ensure the continued security of
Collier County facilities and systems. Failure to notify within four (4) hours of separation may
result in a deduction of$500 per incident.
40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by
representatives of Contractor with full decision-making authority and by County's staff person
who would make the presentation of any settlement reached during negotiations to County for
approval. Failing resolution, and prior to the commencement of depositions in any litigation
between the parties arising out of this Agreement, the parties shall attempt to resolve the
dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State
Page -13-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1440-
6/14/2016 16.E.4.
of Florida. The mediation shall be attended by representatives of Contractor with full decision-
making authority and by County's staff person who would make the presentation of any
settlement reached at mediation to County's board for approval. Should either party fail to
submit to mediation as required hereunder, the other party may obtain a court order requiring
mediation under section 44.102, Fla. Stat.
41. SAFETY. All contractors and subcontractors performing service for Collier County are
required and shall comply with all Occupational Safety and Health Administration (OSHA),
State and County Safety and Occupational Health Standards and any other applicable rules
and regulations. Also all Contractors and subcontractors shall be responsible for the safety of
their employees and any unsafe acts or conditions that may cause injury or damage to any
persons or property within and around the work site.
Collier County Government has authorized the Occupational Safety and Health Administration
(OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of
inspection of any Contractor's work operations. This provision is non-negotiable by any
department/division and/or Contractor. All applicable OSHA inspection criteria apply as well
as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow
OSHA onto a project that is being performed on Collier County Property. Collier County, as the
owner of the property where the project is taking place shall be the only entity allowed to
refuse access to the project. However, this decision shall only be made by Collier County's
Risk Management Division Safety Manager and/or Safety Engineer.
***************************Remainder of page intentionally left blank*******************************
Page -14-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1441-
6/14/2016 16.E.4.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
BOARD OF COUNTY COMMISSIONERS
ATTEST: COLLIER COUNTY, FLORIDA
Dwight E. Brock, Clerk of Courts
By: By:
Donna Fiala, Chairman
Dated:
(Seal)
Compass Construction, Inc.
By:
First Witness Signature
Print Name and Title Print Name and Title
Second Witness
Print Name and Title
Approved a:. t• .r and le•ality:
ky
Jeffrey A. KI7tz t-w, County Attorney
Page -15-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1442- CAO
6/14/2016 16.E.4.
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That , as
Principal, and , as Surety, located at
(Business Address) are held and firmly bound
to as Oblige in the sum of
($ ) for the payment whereof we bind ourselves, our heirs, executors, personal
representatives, successors and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of , 20_,
with Oblige for
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of under-signed representative, pursuant to authority of its governing
body.
Page -16-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
CAO
Packet Page-1443-
6/14/2016 16.E.4.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of 20 , by
, as of , a
corporation, on behalf of the corporation. He/she is personally known to me OR has produced
as identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
Page -17-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1444-
6/14/2016 16.E.4.
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20_, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -18-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1445-
6/14/2016 16.E.4.
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address) are held and firmly bound to
, as Oblige in the sum of
($ ) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
20_, with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page -19-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1446-
6/14/2016 16.E.4.
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
201 , by , as of
a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -20-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
CAO
Packet Page-1447-
6/14/2016 16.E.4.
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of , 20 , by_
, as of
, Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -21-
Agreement#16-6618"General Contractor Services.'
Compass Construction,Inc.
Packet Page -1448-
6/14/2016 16.E.4.
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and it's
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and Owner, dated
20 for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted against the Owner arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS: President
DATE:
Witnesses
[Corporate Seal]
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by , as of
, a corporation, on behalf of the corporation. He/she is
personally known to me or has produced as
identification and did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commissioner No.:
Page -22-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1449-
6/14/2016 16.E.4.
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager) Bid No. 16-6618
(County Department) Project No.
Collier County Board of County Commissioners(the OWNER)or
Collier County Water-Sewer District(the OWNER) Application Date
FROM: (Contractor's Representative) Payment Application No.
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE: (Project
Name)
Original Contract Time: Original Contract Amount: $
Revised Contract Time: Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
Retainage @ 10% thru[insert date] $ and stored to Date $
Retainage @ _% after [insert date] $ Less previous payment(s) $
Percent Work completed to Date: % AMOUNT DUE THIS
Percent Contract Time completed to Date % APPLICATION: $
Liquidated Damages to be Accrued $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER). The value of such
materials and equipment is not relevant and proof of value / cost will not be required; (3) all amounts have been paid for
work which previous payments were issued and received from the OWNER and that current payment is now due; (4)and
CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the
revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
(Signature)
DATE:
(Type Name&Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional : (DP's Name)
(Signature) DATE:
(Type Name&Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager: (Signature) DATE:
(Type Name and Title)
Page -23-
Agreement#16-6618"General Contractor Services"
pass Construction,Inc.
I
Packet Page -1450-
6/14/2016 16.E.4.
EXHIBIT D
CHANGE ORDER
❑Contract Modification 0 Work Order Modification 0 Amendment
Contract#: Change#: Purchase Order#: Project#:
Contractor/Firm Name: Project Name:
Project Manager Name: Department:
Original Contract/Work Order Amount !Original BCC Approval Date; Agenda Item#'
Current BCC Approved Amount ; .. Last BCC Approval Date; Agenda Item#
Current Contract/Work Order Amount SAP Contract Expiration Date(Master)
Dollar Amount of this Change #DIV/01 Total Change from Original Amount
Revised Contract/Work Order Total $ 0.00 #DIV/0' Change from Current BCC Approved Amount
Cumulative Changes $ 0.00 #DIV/01 'Change from Current Amount
Completion Date,Description of'the Task s}Change,an Rationale fo ffie�C tie � s r 4
..., �.x.c .x, ; �.,;.- : ��wz -s ....,. zaEa '; � h1PT' r� ��G �;'*.,�,� ., a.,.`:
Notice to Proceed Original --jApproved d Date
Date completion Date es this change)
#of Days Added Select Tasks 0 Add new task(s) 0 Delete task(s) ❑Change task(s) ❑Other(see
below)
Provide a response to the following: 1.) detailed and specific explanation/rationale of the requested change(s)to the task(s)
and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.)
describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if
needed.
Prepared by: Date:
(Project Manager Name and Division)
Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the
same terms and conditions as contained in the contract /work order indicated above, as fully as if the same were stated in this
acceptance. The adjustment, if any, to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/
Vendor/Consultant/Design Professional arising out of or related to the change set forth herein, including claims for impact and delay
costs.
Accepted by: Date:
(Contractor!Vendor/Consultant/Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Procurement Professional
Page -24-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1451-
6/14/2016 16.E.4.
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -25-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page -1452-
6/14/2016 16.E.4.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
, 20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
, 20_
OWNER
By:
Type Name and Title
Page -26-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1453-
6/14/2016 16.E.4.
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page -27-
Agreement#16-6618"General Contractor Services"
Qrrp® s Construction,Inc.
Packet Page -1454-
6/14/2016 16.E.4.
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on 20_
{
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
Page -28-
Agreement#16-6618"General Contractor Services"
Com.ass Construction,Inc.
Packet Page-1455-
6/14/2016 16.E.4.
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
Page -29-
Agreement#16-6618"General Contractor Services"
Compass Construction,Inc.
Packet Page-1456-
•
6/14/2016 16.E.4.
AGREEMENT16-6618
for
General Contractor Services
THIS AGREEMENT is made and entered into this day of , 2016, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner") and WM. J. Varian Construction
Co., Inc., authorized to do business in the State of Florida, whose business address is 880 23rd St.
SW, Naples, Florida 34117 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. TERM AND COMMENCEMENT. The Agreement shall be for a two (2) year period, commencing
on date of award by the Collier County Board of County Commissioners, and terminating until
such time as all outstanding Work Orders issued prior to the expiration of the Agreement period
have been completed or terminated.
The County may, at its discretion and with the consent of the Contractor, renew the Agreement
under all of the terms and conditions contained in this Agreement for one (1) additional two (2)
year term. The County shall give the Contractor written notice of the County's intention to renew
the Agreement term not less than ten (10) days prior to the end of the Agreement term.
The County Manager, or his designee, may, at his discretion, extend the Agreement under all of
the terms and conditions contained in this Agreement for up to one hundred eighty (180) days.
The Contractor shall commence the Work upon issuance of a Work Order accompanied by a
Notice to Proceed.
2. STATEMENT OF WORK. The Board of County Commissioners deemed six (6) firms to be
qualified and awarded an Agreement to each firm. Each awardee will enter into an Agreement to
provide complete services for General Contractor Services on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP#16-6618 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement.
2.1 The execution of this Agreement shall not be a commitment to the Contractor that any Work
will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
procedure to obtain Work and all Work undertaken by Contractor for Owner pursuant to this
Agreement during the term and any extension of the term of this Agreement. Any County Agency
may utilize the services offered under this Agreement, provided sufficient funds are included in the
budget(s).
Page -1-
0
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1457-
6/14/2016 16.E.4.
2.2 The procedure for obtaining Work under this Agreement is as follows:
For projects with a value up to three thousand ($3,000) dollars is as follows:
• County Staff will select one of the awarded Contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
For projects above three thousand ($3,000) and up to fifty thousand ($50,000) dollars is
as follows:
• A summary of work will be offered to all Contractors under contract. The Contractors will
respond by providing fixed price, lump sum quote following the price methodology in
Section 3.1 within seven (7) working days or as a time agreed to by the County's project
manager for non emergency work and within twenty-four (24) hours for emergency work
from the time of the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all Contractors under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages, if
required.
• The Contractors will respond by providing fixed price, lump sum quote following the price
methodology in Section 3.1 and the requisite quote information requested by the County's
project manager which may include Performance and Payment Bonds requirements,
within seven (7) working days or as a time agreed to by the County's project manager for
non emergency work and within twenty-four (24) hours for emergency work from the time
of the request. If required, the Project Manager shall attach the Bond paperwork to the
SAP requisition and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
Procedures for projects with a value of$250,000 and above are as follows:
• This Agreement is limited for work or projects with an estimated initial value up to
$250,000. This value may be increased after the award by Change Orders for
unanticipated difficulties, work or costs, as set forth in the County's Procurement
Ordinance. Work or projects with an estimated initial value in excess of $250,000 are
outside of the scope of this Agreement, will be competitively bid in accordance with the
County's Procurement Ordinance and will require Board of County Commissioners
approval.
Page -2-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1458-
6/14/2016 16.E.4.
For each awarded Project, as part of the Contract Documents or in each Summary of Work or
Request for Quotation, the Owner reserves the right to specify: the period of completion; collection
of liquidated damages in the event of late completion.
2.3 This Agreement contains the entire understanding between the parties and any modifications
to this Agreement shall be mutually agreed upon in writing by the Contractor and the County, in
compliance with the Procurement Ordinance, as amended and Procurement Procedures in effect
at the time such services are authorized.
2.4 This Agreement shall be the sole Agreement, and shall supersede any prior Agreement
between the parties, for any new work or projects initiated after this Agreement is in effect.
3. THE AGREEMENT SUM. The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation and pursuant to the Price Methodology in Section 3.1.
3.1 Price Methodology:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized.
Only a single lump sum quote is required, no itemized breakdown for the lump sum quote will be
required for quoting or payment purposes. No time and material quotes will be accepted or
required for quoting or payment. Actual invoices for materials, subcontractors, mark-ups, etc. will
not be required for payment purposes, as the lump sum quote does not require a breakdown of
the quote or supporting documentation. Timesheets and/or timecards will not be accepted or
required for quoting or payment purposes to support labor hours, as they are not required for a
lump sum quote.
4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
WM. J. Varian Construction Co., Inc.
880 23rd St. SW
Naples, Florida 34117
Telephone: 239-514-0013
Fax: 239-514-0556
Bills varianconstruction.com
Attention: William Varian, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page -3-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1459-
6/14/2016 16.E.4.
Collier County Government Complex
Procurement Services Division
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Director, Procurement Services Division
Phone: 239-252-8407
Fax: 239-252-6480
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Owner will not be obligated to pay
for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and
other similar taxes associated with the Work or portions thereof, which are applicable during the
performance of the Work.
7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct
any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24)
hours after receiving notice of such violation, conduct, or practice, such suspension to continue
until the violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION. With respect to this Agreement, should the Contractor be found to have failed to
perform Contractor services in a manner satisfactory to the County and requirements of this
Agreement, the County may terminate said Agreement for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall
be sole judge of non-performance. With respect to a particular Project, termination shall be
governed by the terms of the Purchase Order.
9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
Page -4-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1460-
6/14/2016 16.E.4.
10. INSURANCE. The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of$1,000,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that Contractor is required to meet. The same Contractor shall provide County with
certificates of insurance meeting the required insurance provisions.
11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and
paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of
this Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified party or
person described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of a
claim by any party and written notice of such claim being provided to Contractor. Contractor's
obligation to indemnify and defend under this Article 11 will survive the expiration or earlier
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by
the applicable statute of limitations.
Page -5-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1461-
6/14/2016 16.E.4.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be
required to provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment
Bond prior to commencing performance, for the full amount of the Work, which shall act
as a security guaranteeing the performance of the Contractor's work and the payment
by the Contractor to any other party (ies) providing labor and/or materials in connection
with each construction or renovation project performed by the Contractor. The bonds
shall be furnished using the forms prescribed in Exhibit "A".
C. All performance security shall be continued for a six (6) month period beyond the final
completion of the project.
D. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5)
calendar days thereafter, substitute another bond and surety, both of which shall be
subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit"C."
14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any
payments otherwise due Contractor under this Agreement or any other Agreement between
Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it
from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of
the Work by the Contractor; or(g) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other Agreement between
Contractor and Owner.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from
specifications shall be approved in writing by Owner in advance.
0
Page -6-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1462-
6/14/2016 16.E.4.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit a lump sum quote of any cost or time increases or savings it foresees as a result
of the change. If accepted by Owner, the change shall be considered a lump sum change
order quote and follow Section 3.1 of this Agreement. Except in an emergency endangering life
or property, or as expressly set forth herein, no addition or changes to the Work shall be made
except upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of Owner is
authorized to direct any extra or changed work orally. Any modifications to this Agreement
shall be in compliance with the County's Procurement Ordinance and Procurement Procedures
in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an Agreement is reached between Contractor and Owner concerning
the requested changes. Contractor shall promptly perform changes authorized by duly
executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the
Change Order in the manner as Owner and Contractor shall mutually agree.
18. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this
contract in accordance with the Procurement Ordinance, as amended, and Procurement
Procedures and Section 3.1 of this Agreement.
Page -7-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1463-
6/14/2016 16.E.4.
19. COMPLIANCE WITH LAWS. The Contractor agrees to comply, at its own expense, with all
federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements
applicable to the Project, including but not limited to those dealing with taxation, workers'
compensation, equal employment and safety (including, but not limited to, the Trench Safety
Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including
specifically those contractual requirements in F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION
OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT
THE CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
The Contractor must specifically comply with the Florida Public Records Law:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public
agency with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the Contractor
does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records required by
the public agency to perform the service. If the Contractor transfers all public records to
the public agency upon completion of the contract, the Contractor shall destroy any
duplicate public records that are exempt or confidential and exempt from public records
disclosure requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the public
agency, upon request from the public agency's custodian of public records, in a format
that is compatible with the information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to
unilaterally terminate this Agreement immediately.
20. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work. At the completion of the Work, Contractor shall
remove all debris, rubbish and waste materials from and about the Project site, as well as all
tools, appliances, construction equipment and machinery and surplus materials, and shall
leave the Project site clean and ready for occupancy by Owner.
Page -8-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Ino
Packet Page -1464-
6/14/2016 16.E.4.
21. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the
prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or
any part thereof, it shall require that its assignee be bound to it and to assume toward
Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
22. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any
of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's
Proposal, and/or the County's Board approved Executive Summary, this Agreement shall take
precedence.
23. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement
or repair. These warranties are in addition to those implied warranties to which Owner is
entitled as a matter of law.
24. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply
competent employees who are physically capable of performing their employment duties. The
County may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Collier County
projects is not in the best interest of the County.
25. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
26. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Page -9-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1465- �p
6/14/2016 16.E.4.
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
27. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons
or the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the
occurrence of the emergency, if Contractor believes that any significant changes in the Work
or variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations. The Change Order shall be completed in
accordance with Section 3.1 of this Agreement.
If Contractor fails to provide the forty-eight (48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
28. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner)
is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or
such designated portion) is substantially complete and request that Owner issue a Certificate
of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work (or designated portion thereof) to determine the status of
completion. If Owner does not consider the Work (or designated portion) substantially
complete, the Owner shall notify Contractor in writing giving the reasons therefor.
If Owner considers the Work (or designated portion) substantially complete, Owner shall
prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall
fix the date of Substantial Completion for the entire Work (or designated portion thereof) and
include a tentative punchlist of items to be completed or corrected by Contractor before final
payment.
Owner shall have the right to exclude Contractor from the Work and Project site (or designated
portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance
with the Contract Documents and is ready for final inspection and acceptance, Owner will
Page -10-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.co
Packet Page -1466-
6/14/2016 16.E.4.
make such inspection and, if Owner finds the Work acceptable and fully performed under the
Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit F,
recommending that on the basis of Owner's observations and inspections, and the
Contractor's certification that the Work has been completed in accordance with the terms and
conditions of the Contract Documents, that the entire balance found to be due Contractor is
due and payable. Final payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit "B."
(2) Consent of Surety (if applicable) to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to
the acceptability of the Work. Unless and until the Owner is completely satisfied, the final
payment shall not become due and payable.
29. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for
Quotation. The date of substantial completion of the Work (or designated portions thereof) is
the date certified by the Owner when construction is sufficiently complete, in accordance with
the Contract Documents, so Owner can occupy or utilize the Work (or designated portions
thereof) for the use for which it is intended. The Work shall reach final completion and be
ready for final acceptance by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete
the Work within the specified time period, Owner shall be entitled to assess as liquidated
damages, but not as a penalty, the amount specified in the Contract Documents, Summary of
Work, or Request for Quotation for each calendar day thereafter until substantial completion is
achieved.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby
expressly waives and relinquishes any right which it may have to seek characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if Contractor
fails to substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
Page -11-
Agreement#16-6618"General Contractor Services"0WM.J.Varian Construction Co.,Inc
Packet Page-1467-
CN
6/14/2016 16.E.4.
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
30. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the
County by the Facilities Management Division.
31. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set
out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP No. 16-6618, any
addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any
related plans or specifications for any such Quotations or Work Orders.
32. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall
offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value
to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County
Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a.
Prohibition by the individual, firm, and/or any employee of the firm from contact with County
staff for a specified period of time; b. Prohibition by the individual and/or firm from doing
business with the County for a specified period of time, including but not limited to: submitting
bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual
and/or firm for cause.
33. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
34. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. If
these costs are applicable, the costs will be included in the lump sum total and follow Section
3.1 of this Agreement.
35. IMMIGRATION LAW COMPLIANCE. By executing and entering into this Agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure
by the Contractor to comply with the laws referenced herein shall constitute a breach of this
Agreement and the County shall have the discretion to unilaterally terminate this Agreement
immediately.
36. VENUE. Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
37. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages
and agrees to the successful proposer extending the pricing, terms and conditions of this
solicitation or resultant Agreement to other governmental entities at the discretion of the
successful proposer.
Page -12-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc
Packet Page -1468-
6/14/2016 16.E.4.
38. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or
otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall
remain in effect.
39. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as
amended. Background checks are valid for five (5) years and the Contractor shall be
responsible for all associated costs. If required, Contractor shall be responsible for the costs of
providing background checks by the Collier County Facilities Management Division for all
employees that shall provide services to the County under this Agreement. This may include,
but not be limited to, checking federal, state and local law enforcement records, including a
state and FBI fingerprint check, credit reports, education, residence and employment
verifications and other related records. Contractor shall be required to maintain records on
each employee and make them available to the County for at least four (4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check
is valid, as discussed below. All technicians shall have on their shirts the name of the
contractor's business.
The Contractor shall immediately notify the Collier County Facilities Management Division via
e-mail (DL-FMOPS@colliergov.net) whenever an employee assigned to Collier County
separates from their employment. This notification is critical to ensure the continued security of
Collier County facilities and systems. Failure to notify within four (4) hours of separation may
result in a deduction of$500 per incident.
40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by
representatives of Contractor with full decision-making authority and by County's staff person
who would make the presentation of any settlement reached during negotiations to County for
approval. Failing resolution, and prior to the commencement of depositions in any litigation
between the parties arising out of this Agreement, the parties shall attempt to resolve the
dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State
of Florida. The mediation shall be attended by representatives of Contractor with full decision-
making authority and by County's staff person who would make the presentation of any
settlement reached at mediation to County's board for approval. Should either party fail to
submit to mediation as required hereunder, the other party may obtain a court order requiring
mediation under section 44.102, Fla. Stat.
41. SAFETY. All contractors and subcontractors performing service for Collier County are
required and shall comply with all Occupational Safety and Health Administration (OSHA),
State and County Safety and Occupational Health Standards and any other applicable rules
and regulations. Also all Contractors and subcontractors shall be responsible for the safety of
their employees and any unsafe acts or conditions that may cause injury or damage to any
persons or property within and around the work site.
Page -13-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc..
Packet Page -1469-
6/14/2016 16.E.4.
Collier County Government has authorized the Occupational Safety and Health Administration
(OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of
inspection of any Contractor's work operations. This provision is non-negotiable by any
department/division and/or Contractor. All applicable OSHA inspection criteria apply as well
as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow
OSHA onto a project that is being performed on Collier County Property. Collier County, as the
owner of the property where the project is taking place shall be the only entity allowed to
refuse access to the project. However, this decision shall only be made by Collier County's
Risk Management Division Safety Manager and/or Safety Engineer.
***************************Remainder of page intentionally left blank*******************************
Page -14-
Aireement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1470-
6/14/2016 16.E.4.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
BOARD OF COUNTY COMMISSIONERS
ATTEST: COLLIER COUNTY, FLORIDA
Dwight E. Brock, Clerk of Courts
By: By:
Donna Fiala, Chairman
Dated:
(Seal)
WM. J. Varian Construction Co., Inc.
By:
First Witness Signature
Print Name and Title Print Name and Title
Second Witness
Print Name and Title
Approved tie,r and legality:
rii',
Jeffrey A. Kl:"�' mw, County Attorney
Page -15-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1471-
6/14/2016 16.E.4.
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That , as
Principal, and , as Surety, located at
(Business Address) are held and firmly bound
to as Oblige in the sum of
($ ) for the payment whereof we bind ourselves, our heirs, executors, personal
representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of , 20_,
with Oblige for
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of under-signed representative, pursuant to authority of its governing
body.
Page -16-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1472-
6/14/2016 16.E.4.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of 20_, by
, as of , a
corporation, on behalf of the corporation. He/she is personally known to me OR has produced
as identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
(lift
Page -17-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1473-
6/14/2016 16.E.4.
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20_, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -18-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1474-
6/14/2016 16.E.4.
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address) are held and firmly bound to
, as Oblige in the sum of
($ ) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
20_, with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page -19-
Agreement#16-6618"General Contractor Services"
WM,J.Varian Construction Co.,Inc.
Packet Page -1475-
6/14/2016 16.E.4.
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
201_, by , as of
, a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -20-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1476-
6/14/2016 16.E.4.
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of , 20 , by_
, as of
, Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -21-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1477-
6/14/2016 16.E.4.
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and it's
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and Owner, dated
20 for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted against the Owner arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS: President
DATE:
Witnesses
[Corporate Seal]
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by , as of
, a corporation, on behalf of the corporation. He/she is
personally known to me or has produced as
identification and did (did not) take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commissioner No.:
Page -22-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construe- o.,Inc.
Packet Page -1478 4110
-
6/14/2016 16.E.4.
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager) Bid No. 16-6618
(County Department) Project No.
Collier County Board of County Commissioners(the OWNER)or
Collier County Water-Sewer District(the OWNER) Application Date
FROM: (Contractor's Representative) Payment Application No.
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE: (Project
Name)
Original Contract Time: Original Contract Amount: $
Revised Contract Time: Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
Retainage @ 10% thru[insert date] $ and stored to Date $
Retainage @ _%after [insert date] $ Less previous payment(s) $
Percent Work completed to Date: % AMOUNT DUE THIS
Percent Contract Time completed to Date % APPLICATION: $
Liquidated Damages to be Accrued $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through inclusive; (2) title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER). The value of such
materials and equipment is not relevant and proof of value/cost will not be required; (3) all amounts have been paid for
work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and
CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the
revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
DATE: (Signature)
(Type Name&Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional : (DP's Name)
(Signature) DATE:
(Type Name&Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager: (Signature) DATE:
(Type Name and Title)
Page -23- �bj
Agreement#16-6618"General Contractor Seances
WM.J.Varian Construction Co.,Inc.
Packet Page -1479-
6/14/2016 16.E.4.
EXHIBIT D
CHANGE ORDER
❑Contract Modification 0 Work Order Modification D Amendment
Contract#: Change#: Purchase Order#: Project#:
Contractor/Firm Name: Project Name:
Project Manager Name: Department:
Original Contract/Work Order AmountOriginal BCC Approval Date; Agenda Item#4
Current BCC Approved Amount
-- _ Last�BCC Approval Date Agenda Item#
Current Contract/Work Order Amount JSAP Contract Expiration Date (Master)_
Dollar Amount of this Change #DIV/0! Total Change_from Original Amount
Revised Contract/Work Order Total $ 0.00 #DIV/0. /Chan a from Current BCC Approved Amount
Cumulative Changes $ 0.00 #DIV/0! Change from Current Amount
Completion Date;Description Othe Task(s)mite and Rationale for the Change
x .
Notice to Proceed Original IApproved Ki Date
Date ,ompletion Date _....J es this change)
#of Days Added Select Tasks ❑Add new task(s) 0 Delete task(s) ❑Change task(s) 0 Other(see
below)
Provide a response to the following: 1.) detailed and specific explanation/rationale of the requested change(s)to the task(s)
and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.)
describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if
needed.
Prepared by: Date:
(Project Manager Name and Division)
Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the
same terms and conditions as contained in the contract /work order indicated above, as fully as if the same were stated in this
acceptance. The adjustment, if any,to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/
Vendor/Consultant/Design Professional arising out of or related to the change set forth herein, including claims for impact and delay
costs.
Accepted by: Date:
(Contractor/Vendor/Consultant/Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Procurement Professional
Page -24-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,I
Packet Page -1480-
6/14/2016 16.E.4.
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -25-
Aoreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc./a
Packet Page-1481-
6/14/2016 16.E.4.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
, 20_
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
20_
OWNER
By:
Type Name and Title
Page -26-
Agreement#16-6618"General Contractor Se
WM.J.Varian Construction lip
Packet Page-1482-
6/14/2016 16.E.4.
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
0
Page -27-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page-1483-
6/14/2016 16.E.4.
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
0
Page -28-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1484-
6/14/2016 16.E.4.
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
0
Page -29-
Agreement#16-6618"General Contractor Services"
WM.J.Varian Construction Co.,Inc.
Packet Page -1485-
6/14/2016 16.E.4.
AGREEMENT 16-6618
for
General Contractor Services
THIS AGREEMENT is made and entered into this day of , 2016, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner") and Chris-Tel Company of
Southwest Florida, Inc., authorized to do business in the State of Florida, whose business address is
2534-A Edison Avenue, Fort Myers, Florida 33901 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. TERM AND COMMENCEMENT. The Agreement shall be for a two (2) year period, commencing
on date of award by the Collier County Board of County Commissioners, and terminating until
such time as all outstanding Work Orders issued prior to the expiration of the Agreement period
have been completed or terminated.
The County may, at its discretion and with the consent of the Contractor, renew the Agreement
under all of the terms and conditions contained in this Agreement for one (1) additional two (2)
year term. The County shall give the Contractor written notice of the County's intention to renew
the Agreement term not less than ten (10) days prior to the end of the Agreement term.
The County Manager, or his designee, may, at his discretion, extend the Agreement under all of
the terms and conditions contained in this Agreement for up to one hundred eighty (180) days.
The Contractor shall commence the Work upon issuance of a Work Order accompanied by a
Notice to Proceed.
2. STATEMENT OF WORK. The Board of County Commissioners deemed six (6) firms to be
qualified and awarded an Agreement to each firm. Each awardee will enter into an Agreement to
provide complete services for General Contractor Services on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP#16-6618 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement.
2.1 The execution of this Agreement shall not be a commitment to the Contractor that any Work
will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
procedure to obtain Work and all Work undertaken by Contractor for Owner pursuant to this
Agreement during the term and any extension of the term of this Agreement. Any County Agency
may utilize the services offered under this Agreement, provided sufficient funds are included in the
budget(s).
Page -1-
Agreement#16-6618"General Contractor Services'
Chris-Tel Company of Southwest Florida,Inc.
Packet Page -1486-
6/14/2016 16.E.4.
2.2 The procedure for obtaining Work under this Agreement is as follows:
For projects with a value up to three thousand ($3,0001 dollars is as follows:
• County Staff will select one of the awarded Contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
For projects above three thousand ($3,000)and up to fifty thousand ($50,000)dollars is
as follows:
• A summary of work will be offered to all Contractors under contract. The Contractors will
respond by providing fixed price, lump sum quote following the price methodology in
Section 3.1 within seven (7) working days or as a time agreed to by the County's project
manager for non emergency work and within twenty-four (24) hours for emergency work
from the time of the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all Contractors under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages, if
required.
• The Contractors will respond by providing fixed price, lump sum quote following the price
methodology in Section 3.1 and the requisite quote information requested by the County's
project manager which may include Performance and Payment Bonds requirements,
within seven (7) working days or as a time agreed to by the County's project manager for
non emergency work and within twenty-four (24) hours for emergency work from the time
of the request. If required, the Project Manager shall attach the Bond paperwork to the
SAP requisition and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
Procedures for projects with a value of$250,000 and above are as follows:
• This Agreement is limited for work or projects with an estimated initial value up to
$250,000. This value may be increased after the award by Change Orders for
unanticipated difficulties, work or costs, as set forth in the County's Procurement
Ordinance. Work or projects with an estimated initial value in excess of $250,000 are
outside of the scope of this Agreement, will be competitively bid in accordance with the
County's Procurement Ordinance and will require Board of County Commissioners
approval.
Page-2-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1487-
6/14/2016 16.E.4.
For each awarded Project, as part of the Contract Documents or in each Summary of Work or
Request for Quotation, the Owner reserves the right to specify: the period of completion; collection
of liquidated damages in the event of late completion.
2.3 This Agreement contains the entire understanding between the parties and any modifications
to this Agreement shall be mutually agreed upon in writing by the Contractor and the County, in
compliance with the Procurement Ordinance, as amended and Procurement Procedures in effect
at the time such services are authorized.
2.4 This Agreement shall be the sole Agreement, and shall supersede any prior Agreement
between the parties, for any new work or projects initiated after this Agreement is in effect.
3. THE AGREEMENT SUM. The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation and pursuant to the Price Methodology in Section 3.1.
3.1 Price Methodology:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized.
Only a single lump sum quote is required, no itemized breakdown for the lump sum quote will be
required for quoting or payment purposes. No time and material quotes will be accepted or
required for quoting or payment. Actual invoices for materials, subcontractors, mark-ups, etc. will
not be required for payment purposes, as the lump sum quote does not require a breakdown of
the quote or supporting documentation. Timesheets and/or timecards will not be accepted or
required for quoting or payment purposes to support labor hours, as they are not required for a
lump sum quote.
4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
Chris-Tel Company of Southwest Florida, Inc.
2534-A Edison Avenue
Fort Myers, Florida 33901
Telephone: 239-226-0500
Fax: 239-226-0503
hwheelerAchristelconstruction.com
Attention: Howard L. Wheeler, II, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page-3-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1488-
3k
6/14/2016 16.E.4.
Collier County Government Complex
Procurement Services Division
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Director, Procurement Services Division
Phone: 239-252-8407
Fax: 239-252-6480
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Owner will not be obligated to pay
for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and
other similar taxes associated with the Work or portions thereof, which are applicable during the
performance of the Work.
7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct
any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24)
hours after receiving notice of such violation, conduct, or practice, such suspension to continue
until the violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION. With respect to this Agreement, should the Contractor be found to have failed to
perform Contractor services in a manner satisfactory to the County and requirements of this
Agreement, the County may terminate said Agreement for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall
be sole judge of non-performance. With respect to a particular Project, termination shall be
governed by the terms of the Purchase Order.
9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
Page-4-
Aareement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1489-
i
6/14/2016 16.E.4.
10. INSURANCE. The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of$500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of$1,000,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
• Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that Contractor is required to meet. The same Contractor shall provide County with
certificates of insurance meeting the required insurance provisions.
11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and
paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of
this Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified party or
person described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of a
claim by any party and written notice of such claim being provided to Contractor. Contractor's
obligation to indemnify and defend under this Article 11 will survive the expiration or earlier
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred by
the applicable statute of limitations.
Page -5-
Agreement#16-6618`General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page -1490-
6/14/2016 16.E.4.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be
required to provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment
Bond prior to commencing performance, for the full amount of the Work, which shall act
as a security guaranteeing the performance of the Contractor's work and the payment
by the Contractor to any other party (ies) providing labor and/or materials in connection
with each construction or renovation project performed by the Contractor. The bonds
shall be furnished using the forms prescribed in Exhibit"A".
C. All performance security shall be continued for a six (6) month period beyond the final
completion of the project.
D. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5)
calendar days thereafter, substitute another bond and surety, both of which shall be
subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit"C."
14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any
payments otherwise due Contractor under this Agreement or any other Agreement between
Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it
from loss because of: (a)defective Work not remedied; (b)third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of
the Work by the Contractor; or(g) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other Agreement between
Contractor and Owner.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from
specifications shall be approved in writing by Owner in advance.
0
Page -6-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1491-
6/14/2016 16.E.4.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit a lump sum quote of any cost or time increases or savings it foresees as a result
of the change. If accepted by Owner, the change shall be considered a lump sum change
order quote and follow Section 3.1 of this Agreement. Except in an emergency endangering life
or property, or as expressly set forth herein, no addition or changes to the Work shall be made
except upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of Owner is
authorized to direct any extra or changed work orally. Any modifications to this Agreement
shall be in compliance with the County's Procurement Ordinance and Procurement Procedures
in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an Agreement is reached between Contractor and Owner concerning
the requested changes. Contractor shall promptly perform changes authorized by duly
executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the
Change Order in the manner as Owner and Contractor shall mutually agree.
18. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this
contract in accordance with the Procurement Ordinance, as amended, and Procurement
Procedures and Section 3.1 of this Agreement.
Page -7-
Aoreement#16-6618"General Contractor Services'
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1492-
6/14/2016 16.E.4.
19. COMPLIANCE WITH LAWS. The Contractor agrees to comply, at its own expense, with all
federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements
applicable to the Project, including but not limited to those dealing with taxation, workers'
compensation, equal employment and safety (including, but not limited to, the Trench Safety
Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter 119, including
specifically those contractual requirements in F.S. § 119.0701(2)(a)-(b) as stated as follows:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION
OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT
THE CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239)252-8383
The Contractor must specifically comply with the Florida Public Records Law:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public
agency with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the Contractor
does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records required by
the public agency to perform the service. If the Contractor transfers all public records to
the public agency upon completion of the contract, the Contractor shall destroy any
duplicate public records that are exempt or confidential and exempt from public records
disclosure requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the public
agency, upon request from the public agency's custodian of public records, in a format
that is compatible with the information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to
unilaterally terminate this Agreement immediately.
20. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work. At the completion of the Work, Contractor shall
remove all debris, rubbish and waste materials from and about the Project site, as well as all
tools, appliances, construction equipment and machinery and surplus materials, and shall
leave the Project site clean and ready for occupancy by Owner.
Page-8-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1493-
I
6/14/2016 16.E.4.
21. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the
prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or
any part thereof, it shall require that its assignee be bound to it and to assume toward
Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
22. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any
of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's
Proposal, and/or the County's Board approved Executive Summary, this Agreement shalt take
precedence.
23. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents. •
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
If, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement
or repair. These warranties are in addition to those implied warranties to which Owner is
entitled as a matter of law.
24. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply
competent employees who are physically capable of performing their employment duties. The
County may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Collier County
projects is not in the best interest of the County.
25. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
26. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Page-9-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1494- e
IL
6/14/2016 16.E.4.
Contractor is legally liable is responsible for any loss or damage to the Work, or other work or
materials of Owner or Owner's separate contractors, Contractor shall be charged with the
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of any structure to be loaded in any manner that
will endanger the structure, nor shall Contractor subject any part of the Work or adjacent
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark established by the Owner with respect to the
Project. If Contractor, or its subcontractors, agents or anyone, for whom Contractor is legally
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
27. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons
or the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice within forty-eight (48) hours after the
occurrence of the emergency, if Contractor believes that any significant changes in the Work
or variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents is required because of the
action taken in response to an emergency, a Change Order shall be issued to document the
consequences of the changes or variations. The Change Order shall be completed in
accordance with Section 3.1 of this Agreement.
If Contractor fails to provide the forty-eight(48) hour written notice noted above, the Contractor
shall be deemed to have waived any right it otherwise may have had to seek an adjustment to
the Contract Amount or an extension to the Contract Time.
28. COMPLETION. When the entire Work (or any portion thereof designated in writing by Owner)
is ready for its intended use, Contractor shall notify Owner in writing that the entire Work (or
such designated portion) is substantially complete and request that Owner issue a Certificate
of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work (or designated portion thereof) to determine the status of
completion. If Owner does not consider the Work (or designated portion) substantially
complete, the Owner shall notify Contractor in writing giving the reasons therefor.
If Owner considers the Work (or designated portion) substantially complete, Owner shall
prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall
fix the date of Substantial Completion for the entire Work (or designated portion thereof) and
include a tentative punchlist of items to be completed or corrected by Contractor before final
payment.
Owner shall have the right to exclude Contractor from the Work and Project site (or designated
portions thereof) after the date of Substantial Completion, but Owner shall allow Contractor
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor that the Work is completed in accordance
with the Contract Documents and is ready for final inspection and acceptance, Owner will
Page -10-
Aoreement#16.6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,I .0
Packet Page-1495- v
6/14/2016 16.E.4. ,
make such inspection and, if Owner finds the Work acceptable and fully performed under the
Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit F,
recommending that on the basis of Owner's observations and inspections, and the
Contractor's certification that the Work has been completed in accordance with the terms and
conditions of the Contract Documents, that the entire balance found to be due Contractor is
due and payable. Final payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit"B."
(2) Consent of Surety(if applicable)to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to
the acceptability of the Work. Unless and until the Owner is completely satisfied, the final
payment shall not become due and payable.
29. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for
Quotation. The date of substantial completion of the Work (or designated portions thereof) is
the date certified by the Owner when construction is sufficiently complete, in accordance with
the Contract Documents, so Owner can occupy or utilize the Work (or designated portions
thereof) for the use for which it is intended. The Work shall reach final completion and be
ready for final acceptance by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete
the Work within the specified time period, Owner shall be entitled to assess as liquidated
damages, but not as a penalty, the amount specified in the Contract Documents, Summary of
Work, or Request for Quotation for each calendar day thereafter until substantial completion is
achieved.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby
expressly waives and relinquishes any right which it may have to seek characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if Contractor
fails to substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
Page-11-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of.Southwest Florida,Inc
Packet Page-1496- e
6/14/2016 16.E.4.
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
30. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the
County by the Facilities Management Division.
31. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set
out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP No. 16-6618, any
addenda, any QuotationfWork Order made or issued pursuant to this Agreement, and any
related plans or specifications for any such Quotations or Work Orders.
32. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall
offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value
to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County
Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a.
Prohibition by the individual, firm, and/or any employee of the firm from contact with County
staff for a specified period of time; b. Prohibition by the individual and/or firm from doing
business with the County for a specified period of time, including but not limited to: submitting
bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual
and/or firm for cause.
33. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
34. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. If
these costs are applicable, the costs will be included in the lump sum total and follow Section
3.1 of this Agreement.
35. IMMIGRATION LAW COMPLIANCE. By executing and entering into this Agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure
by the Contractor to comply with the laws referenced herein shall constitute a breach of this
Agreement and the County shall have the discretion to unilaterally terminate this Agreement
immediately.
36. VENUE. Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
37. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages
and agrees to the successful proposer extending the pricing, terms and conditions of this
solicitation or resultant Agreement to other governmental entities at the discretion of the
successful proposer.
Page-12-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1497-
6/14/2016 16.E.4.
38. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or
otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall
remain in effect
39. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as
amended. Background checks are valid for five (5) years and the Contractor shall be
responsible for all associated costs. If required, Contractor shall be responsible for the costs of
providing background checks by the Collier County Facilities Management Division for all
employees that shall provide services to the County under this Agreement. This may include,
but not be limited to, checking federal, state and local law enforcement records, including a
state and FBI fingerprint check, credit reports, education, residence and employment
verifications and other related records. Contractor shall be required to maintain records on
each employee and make them available to the County for at least four(4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check
is valid, as discussed below. All technicians shall have on their shirts the name of the
contractor's business.
The Contractor shall immediately notify the Collier County Facilities Management Division via
e-mail (DL-FMOPS(a�colliergov.net) whenever an employee assigned to Collier County
separates from their employment. This notification is critical to ensure the continued security of
Collier County facilities and systems. Failure to notify within four (4) hours of separation may
result in a deduction of$500 per incident.
40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by
representatives of Contractor with full decision-making authority and by County's staff person
who would make the presentation of any settlement reached during negotiations to County for
approval. Failing resolution, and prior to the commencement of depositions in any litigation
between the parties arising out of this Agreement, the parties shall attempt to resolve the
dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State
of Florida. The mediation shall be attended by representatives of Contractor with full decision-
making authority and by County's staff person who would make the presentation of any
settlement reached at mediation to County's board for approval. Should either party fail to
submit to mediation as required hereunder, the other party may obtain a court order requiring
mediation under section 44.102, Fla. Stat.
41. SAFETY. All contractors and subcontractors performing service for Collier County are
required and shall comply with all Occupational Safety and Health Administration (OSHA),
State and County Safety and Occupational Health Standards and any other applicable rules
and regulations. Also all Contractors and subcontractors shall be responsible for the safety of
their employees and any unsafe acts or conditions that may cause injury or damage to any
persons or property within and around the work site.
Page-13-
Agreement#16-6618"General Contractor Services'
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1498-
iJ
6/14/2016 16.E.4.
Collier County Government has authorized the Occupational Safety and Health Administration
(OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of
inspection of any Contractor's work operations. This provision is non-negotiable by any
department/division and/or Contractor. All applicable OSHA inspection criteria apply as well
as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow
OSHA onto a project that is being performed on Collier County Property. Collier County, as the
owner of the property where the project is taking place shall be the only entity allowed to
refuse access to the project. However, this decision shall only be made by Collier County's
Risk Management Division Safety Manager and/or Safety Engineer.
***************************Remainder of page intentionally left blank*******************************
Page-14-
Agreement#16-6618"General Contractor Services'
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1499-
6/14/2016 16.E.4.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
BOARD OF COUNTY COMMISSIONERS
ATTEST: COLLIER COUNTY, FLORIDA
Dwight E. Brock, Clerk of Courts
By: By:
Donna Fiala, Chairman
Dated:
(Seal)
Chris-Tel Company of Southwest Florida, Inc.
By:
First Witness Signature
Print Name and Title Print Name and Title
Second Witness
Print Name and Title
Approved to r land legality:
/t.
Jeffrey A. KI: k.' , County Attorney
Page-15-
Agreement#16-6618"General Contractor Services°
Chris-Tel Company of Southwest Florid.
Packet Page -1500-
6/14/2016 16.E.4.
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
Principal, and as
, as Surety, located at
to (Business Address) are held and firmly bound
toas Oblige in the sum of
) for the payment whereof we bind ourselves, our heirs, executors, personal
representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of 20
with Oblige forin aordance with
_,
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of under-signed representative, pursuant to authority of its governing
body.
Page-16-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1501-
0
t,
6/14/2016 16.E.4.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of 20_, by
, as of , a
corporation, on behalf of the corporation. He/she is personally known to me OR has produced
as identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
Page-17-
0
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1502-
6/14/2016 16.E.4.
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(AFFIX OFFICIAL SEAL) (Legibly Printed)
Notary Public, State of
Commission No.:
Page -18-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1503-
6/14/2016 16.E.4.
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address)are held and firmly bound to
, as Oblige in the sum of
($ ) for the payment whereof we bond ourselves, our he0irs,
executors, personal representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
20_, with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys'fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page-19-
Aareement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1504-
IL.
6/14/2016 16.E.4.
This instrument shall be construed in all respects as a common law bond. It is expressly understood
that the time provisions and statute of limitations under Section 255.05, Florida Statutes, shall not apply to this
bond.
In no event will the Surety u ety be liable in the aggregate to Oblige for more than the penal sum of this
Performance bond regardless of the number of suits that may be filed by Oblige.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
201_, by , as of
a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced as identification and
did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(AFFIX OFFICIAL SEAL) (Legibly Printed)
Notary Public, State of
Commission No.:
Page -20-
Agreement#16-6618"General Contractor Se « "
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1505-
6/14/2016 16.E.4.
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of , 20 , by_
, as of
, Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
Page -21-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1506-
6/14/2016 16.E.4.
EXHIBIT B
• RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authority, personally appeared
who after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and in consideration of $
paid, ("Contractor") releases and waives for itself and it's
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement between Contractor and Owner, dated
20 for the period from to
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted against the Owner arising out of the performance by
Contractor of the Work covered by this Release and Affidavit.
(4) This Release and Affidavit is given in connection with Contractor's [monthly nal]Application for Payment
No.
CONTRACTOR
BY:
ITS: President
Witnesses DATE:
STATE OF [Corporate Seal]
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20 , by
as of
a corporation, on behalf of the corporation. He/she is
personally known to me or has produced as
identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commissioner No.:
Page-22-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Flo oc.
Packet Page-1507-
6/14/2016 16.E.4.
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager) Bid No. 16-6618
(County Department) Project No.
Collier County Board of County Commissioners(the OWNER)or
Collier County Water-Sewer District(the OWNER) Application Date
FROM: (Contractor's Representative) Payment Application No.
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE:
Name) (Project
Original Contract Time: Original Contract Amount $
Revised Contract Time: Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
Retainage @ 10% thru[insert date] $ and stored to Date $
Retainage @ _%after [insert date] $ Less previous payment(s) $
Percent Work completed to Date: % AMOUNT DUE THIS
Percent Contract Time completed to Date % APPLICATION: $
Liquidated Damages to be Accrued $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through inclusive; (2)title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER). The value of such
materials and equipment is not relevant and proof of value/cost will not be required; (3)all amounts have been paid for
work which previous payments were issued and received from the OWNER and that current payment is now due; (4)and
CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the
revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
DATE: (Signature)
(Type Name&Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the e above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional: (DP's Name)
(Signature)DATE:
(Type Name&Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager: (Signature) DATE:
(Type Name and Title)
Page-23-
Agreement#16-6618'General Contractor Services"
Chris-Tel Company of Southwest Flo to.
Packet Page -1508-
1
6/14/2016 16.E.4.
EXHIBIT D
CHANGE ORDER
❑Contract Modification 0 Work Order Modification 0 Amendment
Contract#:I I Change#: Purchase Order#:
l I Project#: I 1
Contractor/Firm Name:I I Project Name: I
I
Project Manager Name:I I Department: I
1
Original Contract/Work Order Amount Original BCC Approval Date; Agenda Item#
Current BCC Approved Amount Last BCC Approval Date; Agenda Item#
Current Contract/Work Order Amount SAP Contract Expiration Date(Master)
Dollar Amount of this Change #DN/0! Total Change from Original Amount
Revised Contract/Work Order Total $ 0.00 #DIV/0! Change from Current BCC A
Cumulative Changes pproved Amount
$ 0.00 #DIV/0! Change from Current Amount
Completion Date,Description of the Task(s)Change,and Rationale for the Change
Notice to Proceed I Loriginal ^Approved es d Datethischange)
Date ompletion Date I
#of Days Added Select Tasks 0 Add new task(s
below) 1 ( ) 0 Delete task(s) 0 Change task(s) 0 Other(see
Provide a response to the following: 1.)detailed and specific explanation/rationale of the requested change(s)to the task(s)
and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.)
describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if
needed.
Prepared by:
(Project Manager Name and Division)
Date:
Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the
same terms and conditions as contained in the contract /work order indicated above, as fully as if the same were stated in this
acceptance. The adjustment, if any,to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/
Vendor/Consultant/Design Professional arising out of or related to the change set forth herein,including claims for impact and delay
costs.
Accepted by:
(Contractor/Vendor/Consultant/Design Professional and Name of Firm,if project applicable)Date:
Approved by:
(Design Professional and Name of Firm,if project applicable) Date:
Approved by:
(Procurement Professional Date:
Page-24-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1509-
5
i
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No.
PROJECT: ENGINEER'S Project No.
6/14/2016 16.E.4.
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -25-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,In
Packet Page-15119
0-
6/14/2016 16.E.4.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on 20
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
, 20__
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
, 20
OWNER
By:
Type Name and Title
Page-26-
Agreement#16-8818`General Contractor Services"
Chris-Tel Company of Southwest Florida,I
Packet Page-1511-
6/14/2016 16.E.4.
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page-27-
Agreement#16-6618"General Contractor Services"
Chris-Tel Company of Southwest Florida,116
Packet Page-1512-
6/14/2016 16.E.4.
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
Page-28-
Agreement#16-6618°General Contractor Services'
Chris-Tel Company of Southwest Florida,In•
Packet Page -1513-
6/14/2016 16.E.4.
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
Page-29-
Aareement#16-6618'General Contractor Services'
Chris-Tel Company of Southwest Florida,Inc.
Packet Page-1514- J
6/14/2016 16.E.4.
AGREEMENT 16-6618
for
General Contractor Services
THIS AGREEMENT is made and entered into this day of , 2016, by and
between the Board of County Commissioners for Collier County, Florida, a political subdivision of the
State of Florida (hereinafter referred to as the "County" or "Owner") and EBL Partners, LLC,
authorized to do business in the State of Florida, whose business address is 1482 Rail Head Blvd.,
Naples, Florida 34110 (hereinafter referred to as the "Contractor").
WITNESSETH:
1. TERM AND COMMENCEMENT. The Agreement shall be for a two (2) year period, commencing
on date of award by the Collier County Board of County Commissioners, and terminating until
such time as all outstanding Work Orders issued prior to the expiration of the Agreement period
have been completed or terminated.
The County may, at its discretion and with the consent of the Contractor, renew the Agreement
under all of the terms and conditions contained in this Agreement for one (1) additional two (2)
year term. The County shall give the Contractor written notice of the County's intention to renew
the Agreement term not less than ten (10) days prior to the end of the Agreement term.
The County Manager, or his designee, may, at his discretion, extend the Agreement under all of
the terms and conditions contained in this Agreement for up to one hundred eighty (180) days.
The Contractor shall commence the Work upon issuance of a Work Order accompanied by a
Notice to Proceed.
2. STATEMENT OF WORK. The Board of County Commissioners deemed six (6) firms to be
qualified and awarded an Agreement to each firm. Each awardee will enter into an Agreement to
provide complete services for General Contractor Services on an as-needed basis as may be
required by the Owner in accordance with the terms and conditions of RFP#16-6618 and the
Contractor's proposal, which is incorporated by reference and made an integral part of this
Agreement.
2.1 The execution of this Agreement shall not be a commitment to the Contractor that any Work
will be awarded to the Contractor. Rather, this Agreement governs the rights and obligation of the
procedure to obtain Work and all Work undertaken by Contractor for Owner pursuant to this
Agreement during the term and any extension of the term of this Agreement. Any County Agency
may utilize the services offered under this Agreement, provided sufficient funds are included in the
budget(s).
Page -1-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page -1515-
k
6/14/2016 16.E.4.
2.2 The procedure for obtaining Work under this Agreement is as follows:
For projects with a value up to three thousand ($3,000) dollars is as follows:
• County Staff will select one of the awarded Contractors who will provide a fixed price,
lump sum quote for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
For projects above three thousand ($3,000) and up to fifty thousand ($50,000) dollars is
as follows:
• A summary of work will be offered to all Contractors under contract. The Contractors will
respond by providing fixed price, lump sum quote following the price methodology in
Section 3.1 within seven (7) working days or as a time agreed to by the County's project
manager for non emergency work and within twenty-four (24) hours for emergency work
from the time of the request.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work shall
not commence without the issuance of a purchase order.
• The work will be given to the Contractor with the lowest responsive lump sum quote.
For projects with a value of more than fifty thousand dollars ($50,000) up to two hundred
fifty thousand dollars ($250,000) is as follows:
• A summary of work will be offered to all Contractors under contract with anticipated
completion schedules, price methodology, and may identify liquidated damages, if
required.
• The Contractors will respond by providing fixed price, lump sum quote following the price
methodology in Section 3.1 and the requisite quote information quested by the County's
u Bonds requirements,
project manager which may include Performance and Payment
within seven (7) working days or as a time agreed to by the County's project manager for
non emergency work and within twenty-four (24) hours for emergency work from the time
of the request. If required, the Project Manager shall attach the Bond paperwork to the
SAP requisition and forward the original paperwork to Procurement Services.
• The Contractors will respond by providing fixed price, lump sum quotes for the work.
• The County's project manager may negotiate terms and conditions, however, work may
not commence without the issuanceContractorpurchase order.
withthe
• The work will be given to the lowest responsive lump sum quote.
Procedures for projects with a value of$250,000 and above are as follows:
• This Agreement is limited for work or projects with an estimated initial value up to
$250,000. This value may be increased after the award by e Procurement
for
unanticipated difficulties, work or costs, as set forth in theCounty's
Ordinance. Work or projects with an estimated initial value in excess of $250,000 are
outside of the scope of this Agreement, will be competitively bid in accordance with the
County's Procurement Ordinance and will require Board of County Commissioners
approval.
0
Page -2-
Agreement#16-6618"General EBL Contractor Services"
Partners,
Packet Page-1516-
A
6/14/2016 16.E4.
For each awarded Project, as part of the Contract Documents or in each Summary of Work or
Request for Quotation, the Owner reserves the right to specify: the period of completion; collection
of liquidated damages in the event of late completion.
2.3 This Agreement contains the entire understanding between the parties and any modifications
to this Agreement shall be mutually agreed upon in writing by the Contractor and the County, in
compliance with the Procurement Ordinance, as amended and Procurement Procedures in effect
at the time such services are authorized.
2.4 This Agreement shall be the sole Agreement, and shall supersede any prior Agreement
between the parties, for any new work or projects initiated after this Agreement is in effect.
3. THE AGREEMENT SUM. The Owner shall pay the Contractor for the performance of the Work
pursuant to the quoted price offered by the Contractor in his response to a specific Request for
Quotation and pursuant to the Price Methodology in Section 3.1.
3.1 Price Methodoloav:
Lump Sum (Fixed Price): a firm fixed total price offering for a project; the risks are transferred
from the County to the contractor; and, as a business practice there are no hourly or material
invoices presented, rather, the contractor must perform to the satisfaction of the County's project
manager before payment for the fixed price contract is authorized.
Only a single lump sum quote is required, no itemized breakdown for the lump sum quote will be
required for quoting or payment purposes. No time and material quotes will be accepted or
required for quoting or payment. Actual invoices for materials, subcontractors, mark-ups, etc. will
not be required for payment purposes, as the lump sum quote does not require a breakdown of
the quote or supporting documentation. Timesheets and/or timecards will not be accepted or
required for quoting or payment purposes to support labor hours, as they are not required for a
lump sum quote.
4. NOTICES. All notices required or made pursuant to this Agreement to be given by the County to
the Contractor shall be made in writing and shall be delivered by hand, by fax, e-mail, or by the
United States Postal Service Department, first class mail service, postage prepaid, addressed to
the following Contractor's address of record:
EBL Partners, LLC
1482 Rail Head Blvd.
Naples, Florida 34110
Telephone: 239-431-5003
Fax: 888-453-1777
pbenson(a7eblpartners.com
Attention: Paul A. Benson, President
All notices required or made pursuant to this Agreement to be given by the Contractor to the
County shall be in writing and shall be delivered by hand, by fax, e-mail, or by United States
Postal Service Department, first class mail service, postage prepaid, addressed to the following
County's address of record:
Page -3- c
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1517-
k
6/14/2016 16.E.4.
Collier County Government Complex
Procurement Services Division
3327 East Tamiami Trail
Naples, Florida 34112
Attention: Director, Procurement Services Division
Phone: 239-252-8407
Fax: 239-252-6480
The Contractor and the County may change the above mailing address at any time upon giving
the other party written notification. All notices under this Service Agreement must be in writing.
5. NO PARTNERSHIP. Nothing herein contained shall create or be construed as creating a
partnership between the County and the Contractor or to constitute the Contractor as an agent of
the County.
6. PERMITS: LICENSES: TAXES. In compliance with Section 218.80, Florida Statutes, all permits
necessary for the prosecution of the Work shall be obtained by the Contractor. Payment for all
such permits issued by the County shall be processed internally by the County. Contractor is not
responsible for paying for permits issued by Collier County, but is responsible for acquiring all
permits. Owner may require the Contractor to deliver internal budget transfer documents to
applicable Collier county agencies when the Contractor is acquiring permits.
All permits, fees and licenses necessary for the prosecution of the Work which are not issued by
Collier County shall be acquired and paid for by the Contractor. Owner will not be obligated to pay
for any permits obtained by Subcontractors. Contractor shall pay all sales, consumer, use and
other similar taxes associated with the Work or portions thereof, which are applicable during the
performance of the Work.
7. NO IMPROPER USE. The Contractor will not use, nor suffer or permit any person to use in any
manner whatsoever, county facilities for any improper, immoral or offensive purpose, or for any
purpose in violation of any federal, state, county or municipal ordinance, rule, order or regulation,
or of any governmental rule or regulation now in effect or hereafter enacted or adopted. In the
event of such violation by the Contractor or if the County or its authorized representative shall
deem any conduct on the part of the Contractor to be objectionable or improper, the County shall
have the right to suspend the Agreement of the Contractor. Should the Contractor fail to correct
any such violation, conduct, or practice to the satisfaction of the County within twenty-four (24)
hours after receiving notice of such violation, conduct, or practice, such suspension to continue
until the violation is cured. The Contractor further agrees not to commence operation during the
suspension period until the violation has been corrected to the satisfaction of the County.
8. TERMINATION. With respect to this Agreement, should the Contractor be found to have failed to
perform Contractor services in a manner satisfactory to the County and requirements of this
Agreement, the County may terminate said Agreement for cause; further the County may
terminate this Agreement for convenience with a thirty (30) day written notice. The County shall
be sole judge of non-performance. With respect to a particular Project, termination shall be
governed by the terms of the Purchase Order.
9. NO DISCRIMINATION. The Contractor agrees that there shall be no discrimination as to race,
sex, color, creed or national origin.
Page -4-
Agreement#16-6618"General Contractor
ctor PartnersServices"
EBL
Packet Page-1518-
6/14/2016 16.E.4.
10. INSURANCE. The Contractor shall provide insurance as follows:
A. Commercial General Liability: Coverage shall have minimum limits of $1,000,000 Per
Occurrence, $2,000,000 aggregate, for Bodily Injury Liability and Property Damage Liability.
This shall include Premises and Operations; Independent contractors; Products and
Completed Operations and Contractual Liability.
B. Business Auto Liability: Coverage shall have minimum limits of $500,000 Per Occurrence,
Combined Single Limit for Bodily Injury Liability and Property Damage Liability. This shall
include Owned Vehicles, Hired and Non-Owned Vehicles and Employee Non-Ownership.
C. Workers' Compensation: Insurance covering all employees meeting Statutory Limits in
compliance with the applicable state and federal laws. The coverage must include Employers'
Liability with a minimum limit of$1,000,000 for each accident.
Special Requirements: Collier County Board of County Commissioners shall be listed as the
Certificate Holder and included as an Additional Insured on the Comprehensive General
Liability.
Current, valid insurance policies meeting the requirement herein identified shall be maintained
by Contractor during the duration of this Agreement. Renewal certificates shall be sent to the
County ten (10) days prior to any expiration date. There shall be a thirty (30) day notification
to the County in the event of cancellation or modification of any stipulated insurance
coverage.
Contractor shall ensure that all subcontractors comply with the same insurance requirements
that Contractor is required to meet. The same Contractor shall provide County with
certificates of insurance meeting the required insurance provisions.
11. INDEMNIFICATION. To the maximum extent permitted by Florida law, the Contractor shall
indemnify and hold harmless Collier County, its officers and employees from any and all liabilities,
damages, losses and costs, including, but not limited to, reasonable attorneys' fees and
paralegals' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the Contractor or anyone employed or utilized by the Contractor in the performance of
this Agreement. This indemnification obligation shall not be construed to negate, abridge or
reduce any other rights or remedies which otherwise may be available to an indemnified party or
person described in this paragraph.
This section does not pertain to any incident arising from the sole negligence of Collier County.
11.1 The duty to defend under this Article 11 is independent and separate from the duty to
indemnify, and the duty to defend exists regardless of any ultimate liability of the Contractor,
Owner and any indemnified party. The duty to defend arises immediately upon presentation of a
claim by any party and written notice of such claim being provided to Contractor. Contractor's
obligation to indemnify and defend under this Article 11 will survive the expiration or earlier
termination of this Agreement until it is determined by final judgment that an action against the
Owner or an indemnified party for the matter indemnified hereunder is fully and finally barred b
the applicable statute of limitations.
Page -5-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1519-
6/14/2016 16.E.4.
12. BONDS.
A. When a construction project is in excess of $200,000, the Contractor(s) shall be
required to provide Payment and Performance Bonds.
B. When required by Owner, the Contractor shall furnish a Performance and/or Payment
Bond prior to commencing performance, for the full amount of the Work, which shall act
as a security guaranteeing the performance of the Contractor's work and the payment
by the Contractor to any other party (ies) providing labor and/or materials in connection
with each construction or renovation project performed by the Contractor. The bonds
shall be furnished using the forms prescribed in Exhibit"A".
C. All performance security shall be continued for a six (6) month period beyond the final
completion of the project.
D. If the surety for any bond furnished by Contractor is declared bankrupt, becomes
insolvent, its right to do business in the State of Florida, or it ceases to meet the
requirements imposed by the Contract Documents, the Contractor shall, within five (5)
calendar days thereafter, substitute another bond and surety, both of which shall be
subject to the Owner's approval.
13. PAYMENTS. Generally, the Contractor will be paid upon completion; however, for Work in
excess of thirty (30) days, the Contractor may indicate on his response to the Request for
Quotation his wish to receive Progress Payments. Subsequent to the first payment, Contractor
must provide Owner with a fully executed Release and Affidavit in the form attached hereto as
Exhibit "B" as a condition precedent to release of each progress payment. All applications for
payment, whether for full payment or a progress payment shall be in writing, and in substantially
the form attached hereto as Exhibit"C."
14. PAYMENTS WITHHELD. Owner may decline to approve any Application for Payment, or
portions thereof, because of defective or incomplete work, outstanding punchlist items,
subsequently discovered evidence or subsequent inspections. The Owner may nullify the whole
or any part of any approval for payment previously issued and Owner may withhold any
payments otherwise due Contractor under this Agreement or any other Agreement between
Owner and Contractor, to such extent as may be necessary in the Owner's opinion to protect it
from loss because of: (a) defective Work not remedied; (b) third party claims failed or reasonable
evidence indicating probable fling of such claims; (c) failure of Contractor to make payment
properly to subcontractors or for labor, materials or equipment; (d) reasonable doubt that the
Work can be completed for the unpaid balance of the Contract Amount; (e) reasonable indication
that the Work will not be completed within the Contract Time; (f) unsatisfactory prosecution of
the Work by the Contractor; or (g) any other material breach of the Contract Documents.
If any conditions described above are not remedied or removed, Owner may, after three (3) days
written notice, rectify the same at Contractor's expense. Owner also may offset against any
sums due Contractor the amount of any liquidated or unliquidated obligations of Contractor to
Owner, whether relating to or arising out of this Agreement or any other Agreement between
Contractor and Owner.
15. SUBMITTALS AND SUBSTITUTIONS. Any substitution of products/materials from
specifications shall be approved in writing by Owner in advance.
Page -6-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1520-
6/14/2016 16.E.4.
16. CONTRACT TIME AND TIME EXTENSIONS.
A. Time is of the essence in the performance of any Work under this Agreement and Contractor
shall diligently pursue the completion of the Work and coordinate the Work being done on the
Project by its subcontractors and materialmen, as well as coordinating its Work with all work of
others at the Project Site, so that its Work or the work of others shall not be delayed or
impaired by any act or omission by Contractor. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences, and procedures as well as coordination
of all portions of the Work under the Contract Documents, and the coordination of Owner's
supplies and contractors.
B. Should Contractor be obstructed or delayed in the prosecution of or completion of the Work as
a result of unforeseeable causes beyond the control of Contractor, and not due to its fault or
neglect, including but not restricted to acts of Nature or of the public enemy, acts of
Government, fires, floods, epidemics, quarantine regulation, strikes or lockouts, Contractor
shall notify the Owner in writing within forty-eight (48) hours after the commencement of such
delay, stating the cause or causes thereof, or be deemed to have waived any right which
Contractor may have had to request a time extension.
C. No interruption, interference, inefficiency, suspension or delay in the commencement or
progress of the Work from any cause whatever, including those for which Owner may be
responsible, in whole or in part, shall relieve Contractor of his duty to perform or give rise to
any right to damages or additional compensation from Owner. Contractor expressly
acknowledges and agrees that it shall receive no damages for delay. Contractor's sole
remedy, if any, against Owner will be the right to seek an extension to the Contract Time;
provided, however, the granting of any such time extension shall not be a condition precedent
to the aforementioned "No Damage for Delay" provision. This paragraph shall expressly apply
to claims for early completion, as well as to claims based on late completion.
17. CHANGES IN THE WORK. Owner shall have the right at any time during the progress of the
Work to increase or decrease the Work. Promptly after being notified of a change, Contractor
shall submit a lump sum quote of any cost or time increases or savings it foresees as a result
of the change. If accepted by Owner, the change shall be considered a lump sum change
order quote and follow Section 3.1 of this Agreement. Except in an emergency endangering life
or property, or as expressly set forth herein, no addition or changes to the Work shall be made
except upon written order of Owner, and Owner shall not be liable to the Contractor for any
increased compensation without such written order. No officer, employee or agent of Owner is
authorized to direct any extra or changed work orally. Any modifications to this Agreement
shall be in compliance with the County's Procurement Ordinance and Procurement Procedures
in effect at the time such modifications are authorized.
A Change Order in the form attached as Exhibit "D" to this Agreement, shall be issued and
executed promptly after an Agreement is reached between Contractor and Owner concerning
the requested changes. Contractor shall promptly perform changes authorized by duly
executed Change Orders. The Contract Amount and Contract Time shall be adjusted in the
Change Order in the manner as Owner and Contractor shall mutually agree.
18. ADDITIONAL ITEMS/SERVICES. Additional items and/or services may be added to this
contract in accordance with the Procurement Ordinance, as amended, and Procurement
Procedures and Section 3.1 of this Agreement.
Page -7-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1521-
6/14/2016 16.E.4.
19. COMPLIANCE WITH LAWS. The Contractor agrees to comply, at its own expense, with all
federal, state and local laws, codes, statutes, ordinances, rules, regulations and requirements
applicable to the Project, including but not limited to those dealing with taxation, workers'
compensation, equal employment and safety (including, but not limited to, the Trench Safety
Act, Chapter 553, Florida Statutes, and the Florida Public Records Law Chapter
apterd 119,s including
specifically those contractual requirements in F.S. § 119.0701(2)(a)-(b)
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION
ICATDUTY OOTN
OF CHAPTER 119, FLORIDAOO THIS THE OCONTRACT, CONTACT
PROVIDE PUBLIC RECORDS RELATING
THE CUSTODIAN OF PUBLIC RECORDS AT:
Communication and Customer Relations Division
3299 Tamiami Trail East, Suite 102
Naples, FL 34112-5746
Telephone: (239) 252-8383
The Contractor must specifically comply with the Florida Public Records Law:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public
agency with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the Contractor
does not transfer the records to the public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public
records in possession of the Contractor or keep and maintain public records required by
the public agency to perform the service. If the Contractor transfers all public records to
the public agency upon completion of the contract, the Contractor shall destroy any
duplicate public records that are exempt or confidential and exempt from public records
disclosure requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the public
agency, upon request from the public agency's custodian of public records, in a format
that is compatible with the information technology systems of the public agency.
If Contractor observes that the Contract Documents are at variance therewith, it shall promptly
notify the County in writing. Failure by the Contractor to comply with the laws referenced herein
shall constitute a breach of this Agreement and the County shall have the discretion to
unilaterally terminate this Agreement immediately.
20. CLEAN UP. Contractor agrees to keep the Project site clean at all times of debris, rubbish
and waste materials arising out of the Work. At the completion of the Work, Contractor shall
remove all debris, rubbish and waste materials from and about the Project site, as well as all
tools, appliances, construction equipment and machinery and surplus materials, and shall
leave the Project site clean and ready for occupancy by Owner.
Page -8-
Agreement#16-6618"General Contractor ne Services'
EBL
Packet Page -1522-
A
6/14/2016 16.E.4.
21. ASSIGNMENT. Contractor shall not assign this Agreement or any part thereof, without the
prior consent in writing of Owner. If Contractor does, with approval, assign this Agreement or
any part thereof, it shall require that its assignee be bound to it and to assume toward
Contractor all of the obligations and responsibilities that Contractor has assumed toward
Owner.
22. ORDER OF PRECEDENCE. In the event of any conflict between or among the terms of any
of the Contract Documents, the terms of the Request for Proposal (RFP), the Contractor's
Proposal, and/or the County's Board approved Executive Summary, this Agreement shall take
precedence.
23. WARRANTY. Contractor shall obtain and assign to Owner all express warranties given to
Contractor or any subcontractors by any materialmen supplying materials, equipment or
fixtures to be incorporated into the Project. Contractor warrants to Owner that any materials
and equipment furnished under the Contract Documents shall be new unless otherwise
specified, and that all Work shall be of good quality, free from all defects and in conformance
with the Contract Documents.
Contractor further warrants to Owner that all materials and equipment furnished under the
Contract Documents shall be applied, installed, connected, erected, used, cleaned and
conditioned in accordance with the instructions of the applicable manufacturers, fabricators,
suppliers or processors except as otherwise provided for in the Contract Documents.
lf, within one (1) year after final completion, any Work is found to be defective or not in
conformance with the Contract Documents, Contractor shall correct it promptly after receipt of
written notice from Owner. Contractor shall also be responsible for and pay for replacement or
repair of adjacent materials or Work which may be damaged as a result of such replacement
or repair. These warranties are in addition to those implied warranties to which Owner is
entitled as a matter of law.
24. STANDARDS OF CONDUCT: PROJECT MANAGER, SUPERVISOR, EMPLOYEES. The
Contractor shall employ people to work on County projects who are neat, clean, well-groomed
and courteous. Subject to the American with Disabilities Act, Contractor shall supply
competent employees who are physically capable of performing their employment duties. The
County may require the Contractor to remove an employee it deems careless, incompetent,
insubordinate or otherwise objectionable and whose continued employment on Collier County
projects is not in the best interest of the County.
25. TESTS AND INSPECTIONS. If the Contract Documents or any codes, laws, ordinances, rules
or regulations of any public authority having jurisdiction over the Project requires any portion of
the Work to be specifically inspected, tested or approved, Contractor shall assume full
responsibility therefore, pay all costs in connection therewith and furnish to the Owner the
required certificates of inspection, testing or approval. All inspections, tests or approvals shall
be performed in a manner and by organizations acceptable to the Owner.
26. PROTECTION OF WORK.
A. Contractor shall fully protect the Work from loss or damage and shall bear the cost of any such
loss or damage until final payment has been made. If Contractor or anyone for whom
Page -9-
Agreement#16-6618"General Contractor Services"
EBL Partners,L
Packet Page-1523-
k
6/14/2016 16.E.4.
Contractor is legally liable is responsible for any loss r damage Cont acto� shall ethe k, or charged other
w with the
ork or
materials of Owner or Owner's separate contractors,
same, and any monies necessary to replace such loss or damage shall be deducted from any
amounts due Contractor.
B. Contractor shall not load nor permit any part of anyu any part of there to be loaed l Work or adjacent
will endanger the structure, nor shall Contractorsubject
property to stresses or pressures that will endanger it.
C. Contractor shall not disturb any benchmark eentslohanyod ne,he forOwner with whom Contractorespect
is legally
Project. If Contractor, or its subcontractors, g
liable, disturbs the Owner's benchmarks, Contractor shall immediately notify Owner. The
Owner shall re-establish the benchmarks and Contractor shall be liable for all costs incurred by
Owner associated therewith.
27. EMERGENCIES. In the event of any emergency affecting the safety or protection of persons
or the Work or property at the Project site or adjacent thereto, Contractor, without special
instruction or authorization from Owner is obligated to act to prevent threatened damage, injury
or loss. Contractor shall give the Owner written notice withinsignificant changes t t(48 hhoursin to ter the
occurrence of the emergency, if Contractor believes that any
ork
or variations from the Contract Documents have been caused thereby.
If the Owner determines that a change in the Contract Documents shall be issuedto document the
because of the
action taken in response to an emergency, a Change O
consequences of the changes or variations. The Change Order shall be completed in
accordance with Section 3.1 of this Agreement.
If Contractor fails to provide the forty-eight t4otherwisewritten
may haunotice
e hadnoted
to seek anthe
adjustment to
shall be deemed to have waived anyright
the Contract Amount or an extension to the Contract Time.
28. COMPLETION. When the entire Work (or any portion thereof n designatedwrg that there itinti e Work by Owner)
is ready for its intended use, Contractor shall notify
(or
such designated portion) is substantially complete and request that Owner issue a Certificate
of Substantial Completion. Within a reasonable time thereafter, Owner and Contractor shall
make an inspection of the Work (or designated portion thereof) to determine the status of
completion. If Owner does not consider the Work (or designated portion) substantially
complete, the Owner shall notify Contractor in writing giving the reasons therefor.
If Owner considers the Work (or designated portion) substantially complete, Owner shall
prepare and deliver to Contractor a Certificate of Substantial Completion, Exhibit E, which shall
fix the date of Substantial Completion for the entire Work (or designated portion thereof) and
include a tentative punchlist of items to be completed or corrected by Contractor before final
payment.
Owner shall have the right to exclude Contractor Com Completion, but Ownerect shall
allow Contractor d
portions thereof) after the date of Substantialp
reasonable access to complete or correct items on the tentative punchlist.
Upon receipt of written certification by Contractor
that
i sped on and acceptance, Owneork is completed in r we
with the Contract Documents and is ready for final
ill
Page -10-
Hreement#1Q-66l8"General-EBL Partners,I LLC®
Packet Page-1524-
6/14/2016 16.E.4.
make such inspection and, if Owner finds the Work acceptable and fully performed under the
Contract Documents, Owner shall promptly issue a Certificate of Final Completion, Exhibit F,
recommending that on the basis of Owner's observations and inspections, and the
Contractor's certification that the Work has been completed in accordance with the terms and
conditions of the Contract Documents, that the entire balance found to be due Contractor is
due and payable. Final payment shall not become due and payable until Contractor submits:
(1) The Release and Affidavit in the form attached as Exhibit"B."
(2) Consent of Surety (if applicable) to final payment.
(3) If required by Owner, other data establishing payment or satisfaction of all obligations,
such as receipt, releases and waivers of liens, arising out of the Contract Documents, to the
extent and in such form as may be designated by Owner.
Owner reserves the right to inspect the Work and make an independent determination as to
the acceptability of the Work. Unless and until the Owner is completely satisfied, the final
payment shall not become due and payable.
29. LIQUIDATED DAMAGES. The "Commencement Date" shall be established in the Notice to
Proceed to be issued by the Owner. Contractor shall commence the work within five (5)
calendar days from the Commencement Date. No Work shall be performed at the Project site
prior to the Commencement Date. Any Work performed by Contractor prior to the
Commencement Date shall be at the sole risk of Contractor.
The Work shall be substantially completed within the time specified in the Request for
Quotation. The date of substantial completion of the Work (or designated portions thereof) is
the date certified by the Owner when construction is sufficiently complete, in accordance with
the Contract Documents, so Owner can occupy or utilize the Work (or designated portions
thereof) for the use for which it is intended. The Work shall reach final completion and be
ready for final acceptance by Owner within the time specified in the Request for Quotation.
Owner and Contractor recognize that since time is of the essence for any work under this
Agreement, Owner will suffer financial loss if the Work is not substantially completed within the
time specified in the Request for Quotation. Should Contractor fail to substantially complete
the Work within the specified time period, Owner shall be entitled to assess as liquidated
damages, but not as a penalty, the amount specified in the Contract Documents, Summary of
Work, or Request for Quotation for each calendar day thereafter until substantial completion is
achieved.
The Project shall be deemed to be substantially completed on the date the Owner issues a
Certificate of Substantial Completion pursuant to the terms hereof. Contractor hereby
expressly waives and relinquishes any right which it may have to seek characterize the above
noted liquidated damages as a penalty, which the parties agree represents a fair and
reasonable estimate of the Owner's actual damages at the time of contracting if Contractor
fails to substantially complete the Work in a timely manner.
When any period of time is referenced by days herein, it shall be computed to exclude the first
day and include the last day of such period. If the last day of any such period falls on a
Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction,
Page -11-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1525-
oVa
6/14/2016 16.E.4.
such day shall be omitted from the computation, and the last day shall become the next
succeeding day which is not a Saturday, Sunday or legal holiday.
30. AGREEMENT ADMINISTRATION. This Agreement shall be administered on behalf of the
County by the Facilities Management Division.
31. COMPONENT PARTS OF THIS AGREEMENT. This Agreement consists of the attached or
referenced component parts, all of which are as fully a part of the Agreement as if herein set
out verbatim, including: Contractor's Proposal, Insurance Certificate(s), RFP No. 16-6618, any
addenda, any Quotation/Work Order made or issued pursuant to this Agreement, and any
related plans or specifications for any such Quotations or Work Orders.
32. PROHIBITION OF GIFTS TO COUNTY EMPLOYEES. No organization or individual shall
offer or give, either directly or indirectly, any favor, gift, loan, fee, service or other item of value
to any County employee, as set forth in Chapter 112, Part III, Florida Statutes, Collier County
Ethics Ordinance No. 2004-05, as amended, and County Administrative Procedure 5311.
Violation of this provision may result in one or more of the following consequences: a.
Prohibition by the individual, firm, and/or any employee of the firm from contact with County
staff for a specified period of time; b. Prohibition by the individual and/or firm from doing
business with the County for a specified period of time, including but not limited to: submitting
bids, RFP, and/or quotes; and, c. immediate termination of any contract held by the individual
and/or firm for cause.
33. SUBJECT TO APPROPRIATION. It is further understood and agreed, by and between the
parties herein that this Agreement is subject to appropriation by the Board of County
Commissioners.
34. SALES TAX. Contractor shall pay all sales, consumer, use and other similar taxes associated
with the Work or portions thereof, which are applicable during the performance of the Work. If
these costs are applicable, the costs will be included in the lump sum total and follow Section
3.1 of this Agreement.
35. IMMIGRATION LAW COMPLIANCE. By executing and entering into this Agreement, the
Contractor is formally acknowledging without exception or stipulation that it is fully responsible
for complying with the provisions of the Immigration Reform and Control Act of 1986 as located
at 8 U.S.C. 1324, et seq. and regulations relating thereto, as either may be amended. Failure
by the Contractor to comply with the laws referenced herein shall constitute a breach of this
Agreement and the County shall have the discretion to unilaterally terminate this Agreement
immediately.
36. VENUE. Any suit or action brought by either party to this Agreement against the other party
relating to or arising out of this Agreement must be brought in the appropriate federal or state
courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
37. OFFER EXTENDED TO OTHER GOVERNMENTAL ENTITIES. Collier County encourages
and agrees to the successful proposer extending the pricing, terms and conditions of this
solicitation or resultant Agreement to other governmental entities at the discretion of the
successful proposer.
Page -12-
Agreement#16-6618"General Contractor Servi
EBL Partners,
Packet Page-1526-
6/14/2016 16.E.4.
38. AGREEMENT TERMS. If any portion of this Agreement is held to be void, invalid, or
otherwise unenforceable, in whole or in part, the remaining portion of this Agreement shall
remain in effect.
39. SECURITY. The Contractor is required to comply with County Ordinance 2004-52, as
amended. Background checks are valid for five (5) years and the Contractor shall be
responsible for all associated costs. If required, Contractor shall be responsible for the costs of
providing background checks by the Collier County Facilities Management Division for all
employees that shall provide services to the County under this Agreement. This may include,
but not be limited to, checking federal, state and local law enforcement records, including a
state and FBI fingerprint check, credit reports, education, residence and employment
verifications and other related records. Contractor shall be required to maintain records on
each employee and make them available to the County for at least four (4) years.
All of Contractor's employees and subcontractors must wear Collier County Government
Identification badges at all times while performing services on County facilities and properties.
Contractor ID badges are valid for one (1) year from the date of issuance and can be renewed
each year at no cost to the Contractor during the time period in which their background check
is valid, as discussed below. All technicians shall have on their shirts the name of the
contractor's business.
The Contractor shall immediately notify the Collier County Facilities Management Division via
e-mail (DL-FMOPS@collieroov.net) whenever an employee assigned to Collier County
separates from their employment. This notification is critical to ensure the continued security of
Collier County facilities and systems. Failure to notify within four (4) hours of separation may
result in a deduction of$500 per incident.
40. DISPUTE RESOLUTION. Prior to the initiation of any action or proceeding permitted by this
Agreement to resolve disputes between the parties, the parties shall make a good faith effort to
resolve any such disputes by negotiation. The negotiation shall be attended by
representatives of Contractor with full decision-making authority and by County's staff person
who would make the presentation of any settlement reached during negotiations to County for
approval. Failing resolution, and prior to the commencement of depositions in any litigation
between the parties arising out of this Agreement, the parties shall attempt to resolve the
dispute through Mediation before an agreed-upon Circuit Court Mediator certified by the State
of Florida. The mediation shall be attended by representatives of Contractor with full decision-
making authority and by County's staff person who would make the presentation of any
settlement reached at mediation to County's board for approval. Should either party fail to
submit to mediation as required hereunder, the other party may obtain a court order requiring
mediation under section 44.102, Fla. Stat.
41. SAFETY. All contractors and subcontractors performing service for Collier County are
required and shall comply with all Occupational Safety and Health Administration (OSHA),
State and County Safety and Occupational Health Standards and any other applicable rules
and regulations. Also all Contractors and subcontractors shall be responsible for the safety of
their employees and any unsafe acts or conditions that may cause injury or damage to any
persons or property within and around the work site.
Page -13-
Agreement#16-6618"General Contractor Service
EBL Partners,LL1 '
Packet Page-1527-
6/14/2016 16.E.4.
Collier County Government has authorized the Occupational Safety and Health Administration
(OSHA) to enter any Collier County Facility, property and/or right-of-way for the purpose of
inspection of any Contractor's work operations. This provision is non-negotiable by any
department/division and/or Contractor. All applicable OSHA inspection criteria apply as well
as all Contractor rights, with one exception. Contractors do not have the right to refuse to allow
OSHA onto a project that is being performed on Collier County Property. Collier County, as the
owner of the property where the project is taking place shall be the only entity allowed to
refuse access to the project. However, this decision shall only be made by Collier County's
Risk Management Division Safety Manager and/or Safety Engineer.
***************************Remainderblank*******************************
of page intentionally left
Page -14-
Agreement#16-6618"General Contractor
EBL Parte
Packet Page-1528-
k
6/14/2016 16.E.4.
IN WITNESS WHEREOF, the Contractor and the County, have each, respectively, by an
authorized person or agent, hereunder set their hands and seals on the date and year first above
written.
BOARD OF COUNTY COMMISSIONERS
ATTEST: COLLIER COUNTY, FLORIDA
Dwight E. Brock, Clerk of Courts
By: By:
Donna Fiala, Chairman
Dated:
(Seal)
EBL Partners, LLC
By:
First Witness Signature
Print Name and Title Print Name and Title
Second Witness
Print Name and Title
Approved a-i o,1,r +1-nd legality:
Jeffrey A. Kl. ='r'.4 , ounty Attorney
Page -15-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1529-
6/14/2016 16.E.4.
EXHIBIT A
PUBLIC PAYMENT BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That , as
Principal, and , as Surety, located at
(Business Address) are held and firmly bound
to as Oblige in the sum of
($ ) for the payment whereof we bind ourselves, our heirs, executors, personal
representatives, successors and assigns, jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of , 20_,
with Oblige for
in accordance with
drawings and specifications, which contract is incorporated by reference and made a part hereof, and
is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payment to all claimants as defined in Section 255.05(1), Florida Statutes,
supplying Principal with labor, materials or supplies, used directly or indirectly by Principal in the
prosecution of the work provided for in the contract, then this bond is void; otherwise it remains in full
force.
Any changes in or under the Contract and compliance or noncompliance with any formalities
connected with the Contract or the changes do not affect sureties obligation under this Bond.
The provisions of this bond are subject to the time limitations of Section 255.0592. In no event
will the Surety be liable in the aggregate to claimants for more than the penal sum of this Payment
Bond, regardless of the number of suits that may be filed by claimants.
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
, 20 , the name of under-signed representative, pursuant to authority of its governing
body.
Page -16-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1530-
6/14/2016 16.E.4.
Signed, sealed and delivered
in the presence of: PRINCIPAL:
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this of 20 , by
, as of , a
corporation, on behalf of the corporation. He/she is personally known to me OR has produced
as identification and did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
0
Page -17-
Aareement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1531-
6/14/2016 16.E.4.
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
20,, by , as
of , Surety, on behalf of Surety. He/She is personally known
to me OR has produced as identification and who did (did not)take an oath.
My Commission Expires: (Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
•
Page -18-
Agreement#16-6618"General C ntr ctorne ce rvi "
EBLC
Packet Page-1532-
1
6/14/2016 16.E.4.
EXHIBIT A-2
PUBLIC PERFORMANCE BOND
Bond No.
Contract No. 16-6618
KNOW ALL MEN BY THESE PRESENTS: That
, as Principal, and
, as Surety, located at
(Business Address) are held and firmly bound to
, as Oblige in the sum of
($ ) for the payment whereof we bond ourselves, our heirs,
executors, personal representatives, successors and assigns,jointly and severally.
WHEREAS, Principal has entered into a contract dated as of the day of
20_, with Oblige for
in accordance with drawings and specifications, which contractor is incorporated by reference and made a pat
hereof, and is referred to as the Contract.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the Contract at the times and in the manner prescribed in the Contract, and
2. Pays Oblige any and all losses, damages, costs and attorneys' fees that Oblige sustains because of
any default by Principal under the Contract, including, but not limited to, all delay damages, whether
liquidated or actual, incurred by Oblige; and
3. Performs the guarantee of all work and materials furnished under the Contract for the time specified
in the Contract, then this bond is void; otherwise it remains in full force. Any changes in or under
the Contract and compliance or noncompliance with any formalities connected with the Contract or
the changes do not affect Sureties obligation under this bond.
The Surety, for value received, hereby stipulates and agrees that no changes, extensions of time,
alterations or additions to the terms of the Contract or other work to be performed hereunder, or the
specifications referred to therein shall in anywise affect its obligations under this bond, and it does hereby
waive notice of any such changes, extensions of time, alternations or additions to the terms of the Contract or
to work or to the specifications.
Page -19-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1533-
6/14/2016 16.E.4.
This instrument shall be construed in all respects as a common Fiorida Statutes, shall not apply to this
that the time provisions and statute of limitations under Section 255 05,
bond.
In no event will the Surety be liable in
the
suits that may be fO d by lige foOr gmoree than the penal sum of this
Performance bond regardless of the number
IN WITNESS WHEREOF, the above parties have executed this instrument this day of
20 , the name of each party being affixed and these presents duly signed by its undersigned
representative, pursuant to authority of its governing body.
Signed, sealed and delivered PRINCIPAL:
in the presence of
By:
Witnesses as to Principal Name:
Its:
STATE OF
COUNTY OF
• The foregoing instrument was acknowledged before me this day of of
201_, by as
a corporation, on behalf of the corporation.
He/She is personally known to me OR has produced
as identification and
did (did not)take an oath.
My Commission Expires: (Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commission No.:
Page -20-
Agreement#16-6618"General EBL ContractorPartners,Service&
Packet Page-1534-
M
6/14/2016 16.E.4.
ATTEST: SURETY:
(Printed Name)
(Business Address)
(Authorized Signature)
Witness as to Surety
(Printed Name)
OR
As Attorney in Fact
(Attach Power of Attorney)
Witnesses
(Business Address)
(Printed Name)
(Telephone Number)
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of , 20 , by_
, as of
, Surety, on behalf of Surety. He/She is personally known to me OR has produced
as identification and who did (did not)take an oath.
My Commission Expires:
(Signature of Notary)
Name:
(Legibly Printed)
(AFFIX OFFICIAL SEAL)
Notary Public, State of
Commission No.:
(I)
Page -21-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1535-
6/14/2016 16.E.4.
EXHIBIT B
RELEASE AND AFFIDAVIT FORM
COUNTY OF COLLIER )
STATE OF FLORIDA )
Before me, the undersigned authoritwhersonally appeared
o after being duly sworn, deposes and says:
(1) In accordance with the Contract Documents and i("Contr
Contractor") releases and waives for itself and it's
paid,
subcontractors, material-men, successors and assigns, all claims demands, damages, costs and expenses,
whether in contract or in tort, against the Board of County Commissioners of Collier County, Florida, relating in
any way to the performance of the Agreement betweenoContractor and Owner, dated
20 for the period from
(2) Contractor certifies for itself and its subcontractors, material-men, successors and assigns, that all charges
for labor, materials, supplies, lands, licenses and other expenses for which Owner might be sued or for which a
lien or a demand against any payment bond might be filed, have been fully satisfied and paid.
(3) Contractor agrees to indemnify, defend and save harmless Owner from all demands or suits, actions,
claims of liens or other charges filed or asserted Affidavit. the Owner arising out of the performance by
Contractor of the Work covered by this Release and
(4) This Release and Affidavit is given in connection with Contractor's [monthly/final] Application for Payment
No.
CONTRACTOR
BY:
ITS: President
DATE:
Witnesses Corporate Seal]
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this day of
, as of
20 by corporation, on behalf of the corporation. He/she is
. a as
personally known to me or has produced
identification and did (did not)take an oath.
My Commission Expires: (Signature of Notary)
NAME:
(Legibly Printed)
(AFFIX OFFICIAL SEAL) Notary Public, State of
Commissioner No.:
Page-22-
Agreement#16-6618"General Contractor ervices"
EBL Pa,LLC
Packet Page-1536-
6/14/2016 16.E.4.
EXHIBIT C
FORM OF CONTRACT APPLICATION FOR PAYMENT
(County Project Manager) Bid No. 16-6618
(County Department) Project No.
Collier County Board of County Commissioners(the OWNER)or
Collier County Water-Sewer District(the OWNER) Application Date
FROM: (Contractor's Representative) Payment Application No.
(Contractor's Name) for Work accomplished through the Date:
(Contractor's Address)
RE: (Project
Name)
Original Contract Time: Original Contract Amount: $
Revised Contract Time: Total Change Orders to Date $
Revised Contract Amount $
Total value of Work Completed
Retainage @ 10% thru[insert date] $ and stored to Date $
Retainage @ %after [insert date] $ Less previous payment(s) $
Percent Work completed to Date: % AMOUNT DUE THIS
Percent Contract Time completed to Date % APPLICATION: $
Liquidated Damages to be Accrued $
CONTRACTOR'S CERTIFICATION: The undersigned CONTRACTOR certifies that: (1) all previous progress payments
received from OWNER on account of Work done under the Contract referred to above have been applied to discharge in
full all obligations of CONTRACTOR incurred in connection with Work covered by prior Applications for Payment
numbered 1 through inclusive; (2)title to all materials and equipment incorporated in said Work or otherwise listed
in or covered by this Application for Payment will pass to OWNER at time of payment free and clear of all liens, claims,
security interests and encumbrances (except such as covered by Bond acceptable to OWNER). The value of such
materials and equipment is not relevant and proof of value/cost will not be required; (3) all amounts have been paid for
work which previous payments were issued and received from the OWNER and that current payment is now due; (4) and
CONTRACTOR agrees that all overruns as shown on the monthly estimate summary shall, in fact, be added to the
revised contract and shall be incorporated into a future Change Order:
By CONTRACTOR: (Contractor's Name)
(Signature)
DATE:
(Type Name&Title)
(shall be signed by a duly authorized representative of CONTRACTOR)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is recommended:
By Design Professional : (DP's Name)
(Signature) DATE:
(Type Name&Title)
Payment to the CONTRACTOR for the above AMOUNT DUE THIS APPLICATION is approved:
By OWNER'S Project Manager: (Signature) DATE:
(Type Name and Title)
Page -23-
Aareement#16-6618"General Contractor Services"
EBL Partners,LL
Packet Page-1537-
6/14/2016 16.E.4.
EXHIBIT D
CHANGE ORDER
0 Contract Modification 0 Work Order Modification 0 Amendment
Contract#: Change#: Purchase Order#: Project#:
Contractor/Firm Name: Project Name:
Project Manager Name: Department:
Original Contract/Work Order Amount Original BCC Approval Date; Agenda Item#_
Current BCC Approved Amount ,Last BCC Approval Date, Agenda Item#
Current Contract/Work Order Amount SAP Contract Expiration Date (Master)
Dollar Amount of this Change #DIV/0' iTotal Change from Original Amount
Revised Contract/Work Order Total $ 0.00 #DIV/0! Change from Current BCC Approved Amount
Cumulative Changes $ 0.00 #DIV/0! Change from Current Amount I
Completion Date,Description of the Task s)4.Change,,and Rationale for the Mange
Notice to Proceed Original (Approved id Date
Date "ompletion Date __.,J es this change)
#of Days Added Select Tasks 0 Add new task(s) 0 Delete task(s) 0 Change task(s) 0 Other(see
below)
Provide a response to the following: 1.) detailed and specific explanation/rationale of the requested change(s)to the task(s)
and / or the additional days added (if requested); 2.) why this change was not included in the original contract; and, 3.)
describe the impact if this change is not processed. Attach additional information from the Design Professional and/or Contractor if
needed.
Prepared by: Date:
(Project Manager Name and Division)
Acceptance of this Change Order shall constitute a modification to contract/work order identified above and will be subject to all the
same terms and conditions as contained in the contract / work order indicated above, as fully as if the same were stated in this
acceptance. The adjustment, if any, to the Contract shall constitute a full and final settlement of any and all claims of the Contractor/
Vendor/Consultant/Design Professional arising out of or related to the change set forth herein, including claims for impact and delay
costs.
Accepted by: Date:
(Contractor/Vendor/Consultant/Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Design Professional and Name of Firm,if project applicable)
Approved by: Date:
(Procurement Professional
Page -24-
Agreement#16.6618"General Contractor Services"
EBL Partners
Packet Page-1538- bJ
6/14/2016 16.E.4.
EXHIBIT E
CERTIFICATE OF SUBSTANTIAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Substantial completion applies to all Work under the Contract documents or to the
following specified parts thereof:
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
substantially complete in accordance with the contract documents on:
DATE OF SUBSTANTIAL COMPLETION
A tentative list of items to be completed or corrected is attached hereto. This list may not be all-
inclusive, and the failure to include an item in it does not alter the responsibility of CONTRACTOR to
complete all the Work in accordance with the Contract Documents. The items in the tentative list
shall be completed or corrected by CONTRACTOR within days of the above date of
Substantial Completion.
Page -25-
Agreement#16-6618"General Contractor Servi e
EBL Partner ,Q;,C
Packet Page-1539-
6/14/2016 16.E.4.
The responsibilities between OWNER and CONTRACTOR for security, operation, safety,
maintenance, heat, utilities, insurance and warranties shall be as follows:
RESPONSIBILITIES:
OWNER:
CONTRACTOR:
The following documents are attached to and made a part of this Certificate:
This certificate does not constitute an acceptance of Work not in accordance with the Contract
Documents nor is it a release of CONTRACTOR'S obligation to complete the Work in accordance
with the Contract Documents.
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Substantial Completion on
, 20_
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Substantial Completion on
, 20_
OWNER
By:
Type Name and Title
Page -26-
Agreement#16-6618"General Contractor Services"
EBL Partners,LLC
Packet Page-1540-
6/14/2016 16.E.4.
EXHIBIT F
CERTIFICATE OF FINAL COMPLETION
OWNER'S Project No. ENGINEER'S Project No.
PROJECT:
CONTRACTOR
Contract For
Contract Date
This Certificate of Final completion applies to all Work under the Contract documents.
To
OWNER
And
To
The Work to which this Certificate applies has been inspected by authorized representatives of
OWNER, CONTRACTOR AND DESIGN PROFESSIONAL, and that Work is hereby declared to be
finally complete in accordance with the contract documents on:
DATE OF FINAL COMPLETION
Page -27-
Aoreement#16-6618"General Contractor Services"
EBL Partners,
Packet Page-1541- v
6/14/2016 16.E.4.
The following warranty is attached to and made a part of this Certificate:
EXHIBIT G
Executed by Design Professional on , 20_
Design Professional
By:
Type Name and Title
CONTRACTOR accepts this Certificate of Final Completion on
20
CONTRACTOR
By:
Type Name and Title
OWNER accepts this Certificate of Final Completion on
20
OWNER
By:
Type Name and Title
Page -28-
Agreement#16-6618"General Contractor Servi --V
EBL Partners,
Packet Page -1542-
6/14/2016 16.E.4.
EXHIBIT G
WARRANTY
In consideration of ten dollars, ($10.00), receipt of which is hereby acknowledged, the undersigned
CONTRACTOR does hereby provide, warrant and guarantee all work done and executed under the
contract either directly performed by the CONTRACTOR or at the express request of the
CONTRACTOR by a SUBCONTRACTOR or CONSULTANT.
Project Name:
Date of Final Completion:
Name and Address of CONTRACTOR:
CONTRACTOR warrants and guarantees the work performed pursuant to the contract shall be free of
all defects of materials and workmanship for a period of one year from the DATE OF FINAL
COMPLETION.
The undersigned party further agrees that it will, at its own expense, replace and/or repair all
defective work and materials and all other work damaged by any defective work upon written demand
by the COUNTY. It is further understood that further consideration for this warranty and guaranty is
the consideration given for the requirement pursuant to the general conditions and specifications
under which the contract was let that such warranty and guaranty would be given.
This warranty and guaranty is in addition to any other warranties or guaranties for the work performed
under the contract and does not constitute a waiver of any rights provided pursuant to Florida
Statutes, Chapter 95, et seq.
DATE:
CONTRACTOR
BY:
Attest:
Page -29-
Agreement#16-6618"General Contractor Services"
EBL Partners
alk
Packet Page -1543grOl
-