Backup Documents 06/23/2015 Item #16F4 (Earth Tech Environmental) GINAL DOCUMENTS CHECKLIST &
NG SLIP
ORI
AC OM ANY ALL ORIGINAL ISENT TOL
���� v F 4
L OOARD OF COUNTY COMMISSIONERS OFFICE FOR SIGNATURE
JUS 24 2.015
COYTI�` TTQRNE` PINK ROUTTIN "
Rim@1 � ocurement Services to the Office Initials Date
Following Addressee(s) (In routing order)
1. Risk Management Risk
2. County Attorney Office County Attorney Office i
•
3. BCC Office Board of County
Commissioners
4.
4. Minutes and Records Clerk of Court's Office
\6111\-- (e( 15 (Z:
5. Return to Procurement Services Procurement Services
Division Contact: Diana De Leon
PRIMARY CONTACT INFORMATION
Name of Primary Diana De Leon for Adam Northrup Phone Number 252-8375
Procurement Staff June 23,2015
Contact and Date
Agenda Date Item was June 23,2015✓ Agenda Item Number 16.F.4
Approved by the BCC
Type of Document Contract Number of Original 2
Attached Documents Attached
PO number or account N/A Solicitation/Contract 15-6397 Earth Tech
number if document is Number/Company Environmental
to be recorded Name
INSTRUCTIONS & CHECKLIST
Initial the Yes column or mark"NIA in the Not Applicable column,whichever is Yes N/A(Not
appropriate. (Initial) Applicable)
1. Does the document require the chairman's original signature? DD
2. Does the document need to be sent to another agency for additional signatures? If yes, N/A
provide the Contact Information(Name;Agency;Address;Phone)on an attached sheet.
3. Original document has been signed/initialed for legal sufficiency. (All documents to be
signed by the Chairman,with the exception of most letters,must be reviewed and signed(_Aut(�
by the Office of the County Attorney.
4. All handwritten strike-through and revisions have been initialed by the County Attorney's N/A
Office and all other parties except the BCC Chairman and the Clerk to the Board
5. The Chairman's signature line date has been entered as the date of BCC approval of the N/A
document or the final negotiated contract date whichever is applicable.
6. "Sign here"tabs are placed on the appropriate pages indicating where the Chairman's DD
signature and initials are required.
7. In most cases(some contracts are an exception), an electronic copy of the document and DD
this routing slip should be provided to the County Attorney's Office before the item is
input into SIRE.
8. The document was approved by the BCC on the date above and all changes made DD
during the meeting have been incorporated in the attached document. The County
Attorney's Office has reviewed the changes,if applicable. -
9. Initials of attorney verifying that the attached document is the version approved by th- "--
BCC,all changes directed by the BCC have been made, and the document is ready ft the
Chairman's signature.
MEMORANDUM 16
F
4
Date: June 26, 2015
To: Diana De Leon, Contracts Technician
Purchasing & General Services Department
From: Martha Vergara, Deputy Clerk
Minutes & Records Department
Re: Contract #15-6397 - "Environmental & Biological Studies"
Contractor: Earth Tech Environmental
Attached is an original copy of the contract referenced above, (Item #16F4)
approved by the Board of County Commissioners on Tuesday, June 23, 2015.
An original contract has been held by the Minutes and Records Department as part of
the Board's Official Record.
If you have any questions, please contact me at 252-7240.
Thank you.
Attachment
16F 4
Contract 15-6397
Environmental & Biological Studies
FIXED TERM CONTRACT FOR SERVICES
THIS AGREEMENT is made and entered into this ;3'day of J.r,e_ 201 , by
and between the Board of County Commissioners for Collier County, Florida, a political subdivision of
the State of Florida (hereinafter referred to as the "COUNTY" or "OWNER") and Earth Tech
Environmental, LLC, authorized to do business in the State of Florida, whose business address is
1455 Rail Head Blvd, Suite 8, Naples, FL 34110, (hereinafter referred to as the "CONSULTANT").
WITNESSETH:
WHEREAS, it is in the best interests of OWNER to be able to obtain CONSULTANT
Environmental and Biological Services expeditiously when a need arises in connection with a
Collier County project; and
NOW, THEREFORE, in consideration of the mutual covenants and provisions contained
herein, the parties hereto agree as follows:
ARTICLE 1
CONSULTANT'S RESPONSIBILITY
1.1 From time to time upon the written request or direction of OWNER as hereinafter provided,
CONSULTANT shall provide to OWNER Environmental and Biological Services (hereinafter the
"Services") as herein set forth. The term "Services" includes all Additional Services authorized by
written Amendment or Change Order as hereafter provided.
1
16F 4
1.2 All Services to be performed by CONSULTANT pursuant to this Agreement shall be in
conformance with the scope of services, which shall be described in a Work Order issued pursuant to
the procedures described herein. The form of the Work Order is set forth in attached Schedule A.
Reference to the term "Work Order" herein, with respect to authorization of Services, includes all
written Amendments or Change Orders to any particular Work Order. CONSULTANT acknowledges
and agrees that each individual Work Order shall not exceed $100,000 unless otherwise approved in
writing by the Board of County Commissioners, and that the total initial compensation for all Work
Orders issued under this Agreement shall not exceed $500,000 annually, unless otherwise approved
in writing by the Board of County Commissioners of Collier County.
1.2.1 All Services must be authorized in writing by OWNER in the form of a Work Order.
CONSULTANT shall not provide any Services to OWNER unless and to the extent they are required in
a written Work Order. Any Services provided by CONSULTANT without a written Work Order shall be
at CONSULTANT'S own risk and OWNER shall have no liability for such Services.
1.2.2 As OWNER identifies certain Services it wishes CONSULTANT to provide pursuant to
the terms of this Agreement, OWNER shall request a proposal from CONSULTANT for such Services,
said proposal to be in compliance with the terms of this Agreement. If the parties reach an agreement
with respect to such Services, including, but not limited to the scope, compensation and schedule for
performance of those Services, a Work Order shall be prepared which incorporates the terms of the
understanding reached by the parties with respect to such Services and if both parties are in
agreement therewith, they shall jointly execute the Work Order.
2 o`aJ
1.2.3 Upon execution of a Work Order as aforesaid, CONSULTANT agrees to promptly
provide the Services required thereby, in accordance with the terms of this Agreement and the subject
Work Order.
1.2.4 It is mutually understood and agreed that the nature, amount and frequency of the
Services shall be determined solely by OWNER and that OWNER does not represent or guarantee
unto CONSULTANT that any specific amount of Services will be requested or required of
CONSULTANT pursuant to this Agreement.
1.2.5 CONSULTANT shall have no authority to act as the agent of OWNER under this
Agreement or any Work Order, or to obligate OWNER in any manner or way.
1.2.6 All duly executed Work Orders (including all written Amendments or Change Orders
thereto) are hereby incorporated into and made a part of this Agreement by reference.
1.3 CONSULTANT hereby designates Donn Brown as its Principal in Charge (hereinafter referred
to as the "Principal in Charge") with full authority to bind and obligate CONSULTANT on all matters
arising out of or relating to this Agreement. In each Work Order CONSULTANT will designate a
qualified Environmental and Biological Services professional to serve as CONSULTANT'S project
coordinator for the Services to be provided under that Work Order (hereinafter referred to as the
"Project Coordinator"). The Project Coordinator is authorized and responsible to act on behalf of the
CONSULTANT with respect to directing, coordinating and administering all aspects of the Services to
be provided and performed under the Work Order. Further, the Project Coordinator has full authority
to bind and obligate the CONSULTANT on all matters arising out of or relating to the Work Order.
The CONSULTANT agrees that the Principal in Charge and the Project Coordinators shall devote
whatever time is required to satisfactorily manage the services to be provided and performed by the
3 T;_))
16F 4
CONSULTANT under the Work Order. CONSULTANT further agrees that the Principal in Charge
and Project Coordinators shall not be removed by CONSULTANT without OWNER'S prior written
approval, and if so removed must be immediately replaced with a person acceptable to OWNER.
1.4 CONSULTANT agrees, within fourteen (14) calendar days of receipt of a written request from
OWNER to promptly remove and replace the Principal in Charge or any Project Coordinator, or any
other personnel employed or retained by the CONSULTANT, or any subconsultants or subcontractors
or any personnel of any such subconsultants or subcontractors engaged by the CONSULTANT to
provide and perform any of the Services pursuant to the requirements of this Agreement or any
applicable Work Order, said request may be made with or without cause. Any personnel so removed
must be immediately replaced with a person acceptable to OWNER.
1.5 The CONSULTANT represents to the OWNER that it has expertise and experience in the type
of professional Environmental and Biological Services that will be required under this Agreement.
The CONSULTANT agrees that all services to be provided by CONSULTANT pursuant to this
Agreement shall be subject to the OWNER'S review and approval and shall be in accordance with the
generally accepted standards of professional practice in the State of Florida, as well as in accordance
with all applicable laws, statutes, including but not limited to ordinances, codes, rules, regulations and
requirements of any governmental agencies, and the Florida Building Code where applicable, which
regulate or have jurisdiction over the Services to be provided and performed by CONSULTANT
hereunder, the Local Government Prompt Payment Act (218.735 and 218.76 F.S.), as amended, and
the Florida Public Records Law Chapter 119 (including specifically those contractual requirements at
F.S. § 119.0701(2)(a)-(d) and (3)) as follows:
4
1 F
(2) In addition to other contract requirements provided by law, each public agency contract
for services must include a provision that requires the contractor to comply with public records laws,
specifically to:
(a) Keep and maintain public records that ordinarily and necessarily would be required by the
public agency in order to perform the service.
(b) Provide the public with access to public records on the same terms and conditions that
the public agency would provide the records and at a cost that does not exceed the cost
provided in this chapter or as otherwise provided by law.
(c) Ensure that public records that are exempt or confidential and exempt from public records
disclosure requirements are not disclosed except as authorized by law.
(d) Meet all requirements for retaining public records and transfer, at no cost, to the public
agency all public records in possession of the contractor upon termination of the contract
and destroy any duplicate public records that are exempt or confidential and exempt from
public records disclosure requirements. All records stored electronically must be provided
to the public agency in a format that is compatible with the information technology
systems of the public agency.
(3) If a contractor does not comply with a public records request, the public agency shall
enforce the contract provisions in accordance with the contract.
In the event of any conflicts in these requirements, the CONSULTANT shall notify the OWNER
of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of
each such conflict. OWNER'S approval of any design documents in no way relieves CONSULTANT
of its obligation to deliver complete and accurate documents necessary for successful completion of
the Services required under the subject Work Order.
1.6 CONSULTANT agrees not to divulge, furnish or make available to any third person, firm or
organization, without OWNER'S prior written consent, or unless incident to the proper performance of
5
16F 4
the CONSULTANT'S obligations hereunder, or in the course of judicial or legislative proceedings
where such information has been properly subpoenaed, any non-public information concerning the
Services to be rendered by CONSULTANT hereunder, and CONSULTANT shall require all of its
employees, agents, subconsultants and subcontractors to comply with the provisions of this
paragraph. CONSULTANT shall provide OWNER prompt written notice of any such subpoenas.
1.7 The County reserves the right to deduct portions of the (monthly) invoiced (task) amount for
the following: Tasks not completed within the expressed time frame, including required deliverables,
incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements
and/or codes and ordinances applicable to Consultant's performance of the work as related to the
project. This list is not deemed to be all-inclusive, and the County reserves the right to make sole
determination regarding deductions. After notification of deficiency, if the Consultant fails to correct
the deficiency within the specified timeframe, these funds would be forfeited by the Consultant. The
County may also deduct or charge the Consultant for services and/or items necessary to correct the
deficiencies directly related to the Consultant's non-performance whether or not the County obtained
substitute performance.
ARTICLE 2
ADDITIONAL SERVICES OF CONSULTANT
2.1 If authorized in writing by Owner through an Amendment or Change Order to a Work Order,
CONSULTANT shall furnish or obtain from others Additional Services beyond those Services
originally authorized in the Work Order. The agreed upon scope, compensation and schedule for
Additional Services shall be set forth in the Amendment or Change Order authorizing those Additional
Services. With respect to the individuals with authority to authorize Additional Services under this
6
Agreement, such authority will be as established in OWNER'S Purchasing Ordinance and Procedures
in effect at the time such services are authorized. Except in an emergency endangering life or
property, any Additional Services must be approved in writing via an Amendment or Change Order to
the subject Work Order prior to starting such services. OWNER will not be responsible for the costs
of Additional Services commenced without such express prior written approval. Failure to obtain such
prior written approval for Additional Services will be deemed: (i) a waiver of any claim by
CONSULTANT for such Additional Services and (ii) an admission by CONSULTANT that such Work
is not additional but rather a part of the Services originally required of CONSULTANT under the
subject Work Order. If OWNER determines that a change in a Work Order is required because of the
action taken by CONSULTANT in response to an emergency, an Amendment or Change Order shall
be issued to document the consequences of the changes or variations, provided that CONSULTANT
has delivered written notice to OWNER of the emergency within forty-eight (48) hours from when
CONSULTANT knew or should have known of its occurrence. Failure to provide the forty-eight (48)
hour written notice noted above, waives CONSULTANT'S right it otherwise may have had to seek an
adjustment to its compensation or time of performance under the subject Work Order.
ARTICLE 3
OWNER'S RESPONSIBILITIES
3.1 For each Work Order, OWNER shall designate in writing a project manager to act as
OWNER'S representative with respect to the Services to be rendered under the Work Order
(hereinafter referred to as the "Project Manager"). The Project Manager shall have authority to
transmit instructions, receive information, interpret and define OWNER'S policies and decisions with
respect to CONSULTANT'S Services under the Work Order. However, the Project Manager is not
7
6 c
;i1
authorized to issue any verbal or written orders or instructions to the CONSULTANT that would have
the effect, or be interpreted to have the effect, of modifying or changing in any way whatever:
(a) The scope of Services to be provided and performed by the CONSULTANT as
set forth in the Work Order;
(b) The time the CONSULTANT is obligated to commence and complete all such
Services as set forth in the Work Order; or
(c) The amount of compensation the OWNER is obligated or committed to pay the
CONSULTANT as set forth in the Work Order.
3.2 The Project Manager shall:
(a) Review and make appropriate recommendations on all requests submitted by the
CONSULTANT for payment for services and work provided and performed in
accordance with this Agreement;
(b) Provide all criteria and information requested by CONSULTANT as to OWNER'S
requirements for the Services specified in the Work Order, including design
objectives and constraints, space, capacity and performance requirements,
flexibility and expandability, and any budgetary limitations;
(c) Upon request from CONSULTANT, assist CONSULTANT by placing at
CONSULTANT'S disposal all available information in the OWNER'S possession
pertinent to the Services specified in the Work Order, including existing
specifications, product literature, previous reports and any other data relative to
the subject Work Order;
8
16F 4
(d) Arrange for access to and make all provisions for CONSULTANT to enter the site
(if any) set forth in the Work Order to perform the Services to be provided by
CONSULTANT under the subject Work Order; and
(e) Provide notice to CONSULTANT of any deficiencies or defects discovered by the
OWNER with respect to the Services to be rendered by CONSULTANT
hereunder.
ARTICLE 4
TIME
4.1 Each Work Order will have a time schedule ("Schedule") for the performance of the Services
required under the subject Work Order. Services to be rendered by CONSULTANT shall be
commenced, performed and completed in accordance with the Work Order and the Schedule. Time
is of the essence with respect to the performance of the Services under each Work Order.
4.2 Should CONSULTANT be obstructed or delayed in the prosecution or completion of the
Services as a result of unforeseeable causes beyond the control of CONSULTANT, and not due to its
own fault or neglect, including but not restricted to acts of nature or of public enemy, acts of
government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs,
then CONSULTANT shall notify OWNER in writing within five (5) working days after commencement
of such delay, stating the specific cause or causes thereof, or be deemed to have waived any right
which CONSULTANT may have had to request a time extension for that specific delay.
4.3 Unless otherwise expressly provided in the Work Order, no interruption, interference,
inefficiency, suspension or delay in the commencement or progress of CONSULTANT'S Services
from any cause whatsoever, including those for which OWNER may be responsible in whole or in
part, shall relieve CONSULTANT of its duty to perform or give rise to any right to damages or
9
1 6 F
additional compensation from OWNER. CONSULTANT'S sole remedy against OWNER will be the
right to seek an extension of time to the Schedule; provided, however, the granting of any such time
extension shall not be a condition precedent to the aforementioned "No Damage For Delay" provision.
This paragraph shall expressly apply to claims for early completion, as well as claims based on late
completion.
4.4 Should the CONSULTANT fail to commence, provide, perform or complete any of the Services
to be provided hereunder in a timely manner, in addition to any other rights or remedies available to
the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all
payments due and owing to the CONSULTANT under this Agreement (including any and all Work
Orders) until such time as the CONSULTANT resumes performance of its obligations hereunder in
such a manner so as to reasonably establish to the OWNER'S satisfaction that the CONSULTANT'S
performance is or will shortly be back on schedule.
4.5 In no event shall any approval by OWNER authorizing CONSULTANT to continue performing
Work under any particular Work Order or any payment issued by OWNER to CONSULTANT be
deemed a waiver of any right or claim OWNER may have against CONSULTANT for delay or any
other damages hereunder.
4.6 The period of service shall be from the date of execution of this Agreement through one (1)
year from that date, or until such time as all outstanding Work Orders issued prior to the expiration of
the Agreement period have been completed. This Agreement is for one (1) year and may be renewed
annually for four (4) additional 1 year periods. Any such annual renewal shall be agreed to, in writing,
by both parties.
10
16F 4
ARTICLE 5
COMPENSATION
5.1 Compensation and the manner of payment of such compensation by the OWNER for Services
rendered hereunder by CONSULTANT shall be as prescribed in each Work Order. CONSULTANT
agrees to furnish to OWNER, after the end of each calendar month, or as specified in the Work
Order, a comprehensive and itemized statement of charges for the Services performed and rendered
by CONSULTANT during that time period, and for any OWNER authorized reimbursable expenses as
herein below defined, incurred and/or paid by CONSULTANT during that time period. The monthly
statement shall be in such form and supported by such documentation as may be required by
OWNER. All such statements shall be on CONSULTANT'S letterhead and shall indicate the
Agreement Number, Work Order Number, Purchase Order Number and Project Site description (if
any).
5.2 The compensation (whether based upon a negotiated lump sum, time and materials, hourly
with a cap or some other agreed to format) contained in each separate Work Order shall be based on
the hourly rates as set forth and identified in Schedule B which is attached hereto, for the time
reasonably expended by CONSULTANT'S personnel in performing the Services. The Rate Schedule
may be updated by mutual agreement on an annual basis, in conjunction with the annual renewal of
this Agreement provided for in paragraph 4.6 above, as directed by OWNER.
5.2.1 OWNER agrees to reimburse CONSULTANT for all necessary and reasonable
reimbursable expenses incurred or paid by CONSULTANT in connection with CONSULTANT'S
performance of the Services, at its direct cost with no markup, to the extent such reimbursement is
permitted in the Work Order and in accordance with Section 112.061, F.S., or as set forth below.
11
16F 4
5.2.2 Reimbursable expenses shall be invoiced for the expenditures incurred by the
CONSULTANT as follows:
5.2.2.1. Expenses of transportation and living when traveling in connection with
each Work Order, except for local travel within Collier or Lee Counties, as provided in
Section 112.061, F.S., and all Contract-related mileage for trips that are from/to
destinations outside of Collier or Lee Counties approved by OWNER.
5.2.2.2 Expenses for reproducing documents that exceed the number of
documents described in this Agreement and postage and handling of Drawings and
Specifications, including duplicate sets at the completion of each Work Order for the
OWNER'S review and approval.
5.2.2.3. Expense of overtime work requiring higher than regular rates approved in
advance and in writing by OWNER.
5.2.2.4. Expense of models for the OWNER'S use.
5.2.2.5 Fees paid for securing approval of authorities having jurisdiction over the
Work Order required under the applicable Work Order.
5.2.2.6 Other items on request and approved in writing by the OWNER.
5.2.3 CONSULTANT shall obtain the prior written approval of OWNER before incurring any of
the aforesaid reimbursable expenses, and absent such prior approval, no expenses incurred by
CONSULTANT will be deemed to be a reimbursable expense.
5.3 CONSULTANT shall bear and pay all overhead and other expenses, except for authorized
reimbursable expenses, incurred by CONSULTANT in the performance of the Services.
12
16F 4
5.4 Prior to issuing any Work Order pursuant to this Agreement, OWNER may request that
CONSULTANT in writing advise OWNER of (i) the estimated time of CONSULTANT'S personnel and
the estimated fees thereof for the proposed work to be specified in the Work Order; and (ii) the
estimated charge to OWNER for the reimbursable expenses applicable to the contemplated Services
to be performed by CONSULTANT under the proposed Work Order. CONSULTANT shall promptly
supply such estimate to OWNER based on CONSULTANT'S good faith analysis.
5.5 CONSULTANT agrees that, with respect to any subconsultant or subcontractor to be utilized
by CONSULTANT on any particular Work Order, CONSULTANT shall be limited to a maximum
markup of five percent (5%) on the fees and expenses associated with such subconsultants and
subcontractors.
5.6 Payments for Basic Services and Additional Basic Services as set forth herein, or in the Work
Order shall be made upon presentation of the CONSULTANT'S itemized invoice approved by
OWNER.
5.6.1 Payments will be made for services furnished, delivered, and accepted, upon receipt and
approval of invoices submitted on the date of services or within six (6) months after completion of
contract. Any untimely submission of invoices beyond the specified deadline period is subject to non-
payment under the legal doctrine of"laches" as untimely submitted. Time shall be deemed of the
essence with respect to the timely submission of invoices under this agreement.
5.7 Records of Reimbursable Expenses shall be kept on a generally recognized accounting basis.
5.8 The County reserves the right to deduct portions of the (monthly) invoiced (task) amount for
the following: Tasks not completed within the expressed time frame, including required deliverables,
13
16F 4
incomplete and/or deficient documents, failure to comply with local, state and/or federal requirements
and/or codes and ordinances applicable to Consultant's performance of the work as related to the
project. This list is not deemed to be all-inclusive, and the County reserves the right to make sole
determination regarding deductions. After notification of deficiency, if the Consultant fails to correct
the deficiency within the specified timeframe, these funds would be forfeited by the Consultant. The
County may also deduct or charge the Consultant for services and/or items necessary to correct the
deficiencies directly related to the Consultant's non-performance.
ARTICLE 6
OWNERSHIP OF DOCUMENTS
6.1 Upon the completion or termination of each Work Order, as directed by OWNER,
CONSULTANT shall deliver to OWNER copies or originals of all records, documents, drawings,
notes, tracings, plans, specifications, maps, evaluations, reports and other technical data, other than
working papers, prepared or developed by or for CONSULTANT under the applicable Work Order
("Project Documents"). OWNER shall specify whether the originals or copies of such Project
Documents are to be delivered by CONSULTANT. CONSULTANT shall be solely responsible for all
costs associated with delivering to OWNER the Project Documents. CONSULTANT, at its own
expense, may retain copies of the Project Documents for its files and internal use.
6.2 Notwithstanding anything in this Agreement to the contrary and without requiring OWNER to
pay any additional compensation, CONSULTANT hereby grants to OWNER a nonexclusive,
irrevocable license in all of the Project Documents for OWNER'S use with respect to the applicable
authorized project or task. CONSULTANT warrants to OWNER that it has full right and authority to
grant this license to OWNER. Further, CONSULTANT consents to OWNER'S use of the Project
14 d7
O
16F . 4
Documents to complete the subject project or task following CONSULTANT'S termination for any
reason or task. CONSULTANT also acknowledges OWNER may be making Project Documents
available for review and information to various third parties and hereby consents to such use by
OWNER.
ARTICLE 7
MAINTENANCE OF RECORDS
7.1 CONSULTANT will keep adequate records and supporting documentation which concern or
reflect the Services hereunder. The records and documentation will be retained by CONSULTANT
for a minimum of five (5) years from (a) the date of termination of this Agreement or (b) the date the
Work Order is completed, whichever is later, or such later date as may be required by law. OWNER,
or any duly authorized agents or representatives of OWNER, shall, free of charge, have the right to
audit, inspect and copy all such records and documentation as often as they deem necessary during
the period of this Agreement and during the five (5) year period noted above, or such later date as
may be required by law; provided, however, such activity shall be conducted only during normal
business hours.
7.2 The records specified above in paragraph 7.1 include accurate time records, which
CONSULTANT agrees to keep and maintain, from day to day, showing the time expended by each
principal and employee of CONSULTANT in performing the Services and therein specifying the
services performed by each, with all such time records to be kept within one-half of an hour. At the
request of OWNER, or as specified in the Work Order, CONSULTANT shall furnish to OWNER any of
the aforesaid time records, as well as invoices or proofs showing CONSULTANT'S incurrence and/or
payment of any reimbursable expenses.
15
ARTICLE 8
• 4
444,
INDEMNIFICATION
8.1 To the maximum extent permitted by law, CONSULTANT shall indemnify and hold harmless
OWNER, its officers and employees from any and all liabilities, damages, losses and costs, including,
but not limited to, reasonable attorneys' fees and paralegals' fees, to the extent caused by the
negligence, recklessness, or intentionally wrongful conduct of CONSULTANT or anyone employed or
utilized by the CONSULTANT in the performance of this Agreement. This indemnification obligation
shall not be construed to negate, abridge or reduce any other rights or remedies which otherwise may
be available to an indemnified party or person described in this paragraph 8.1.
8.2 The duty to defend under this Article 8 is independent and separate from the duty to indemnify,
and the duty to defend exists regardless of any ultimate liability of the CONSULTANT, OWNER and
any indemnified party. The duty to defend arises immediately upon presentation of a claim by any
party and written notice of such claim being provided to CONSULTANT. CONSULTANT'S obligation
to indemnify and defend under this Article 8 will survive the expiration or earlier termination of this
Agreement until it is determined by final judgment that an action against the OWNER or an
indemnified party for the matter indemnified hereunder is fully and finally barred by the applicable
statute of limitations.
16
ARTICLE 9 1 6 F 4
INSURANCE
9.1 CONSULTANT shall obtain and carry, at all times during its performance under the Contract
Documents, insurance of the types and in the amounts described herein and further set forth in
Schedule C to this Agreement.
9.2 All insurance shall be from responsible companies duly authorized to do business in the State
of Florida.
9.3 All insurance policies required by this Agreement shall include the following provisions and
conditions by endorsement to the policies:
9.3.1 All insurance policies, other than the Business Automobile policy, Professional Liability
policy, and the Workers Compensation policy, provided by CONSULTANT to meet the requirements of
this Agreement shall name Collier County Board of County Commissioners, Collier County, Florida, as
an additional insured as to the operations of CONSULTANT under this Agreement and shall contain a
severability of interests provisions.
9.3.2 Companies issuing the insurance policy or policies shall have no recourse against
OWNER for payment of premiums or assessments for any deductibles which all are at the sole
responsibility and risk of CONSULTANT.
9.3.3 All insurance coverages of CONSULTANT shall be primary to any insurance or self-
insurance program carried by OWNER, and the "Other Insurance" provisions of any policies obtained
by CONSULTANT shall not apply to any insurance or self-insurance program carried by OWNER.
17
16F 4
9.3.4 The Certificates of Insurance, which are to be provided in an Occurrence Form
patterned after the current I.S.O. form with no limiting endorsements, must reference and identify this
Agreement.
9.3.5 All insurance policies shall be fully performable in Collier County, Florida, and shall be
construed in accordance with the laws of the State of Florida.
9.4 CONSULTANT, its subconsultants and OWNER shall waive all rights against each other for
damages covered by insurance to the extent insurance proceeds are paid and received by OWNER,
except such rights as they may have to the proceeds of such insurance held by any of them.
9.5 All insurance companies from whom CONSULTANT obtains the insurance policies required
hereunder must meet the following minimum requirements:
9.5.1 The insurance company must be duly licensed and authorized by the Department of
Insurance of the State of Florida to transact the appropriate insurance business in the State of Florida.
9.5.2 The insurance company must have a current A. M. Best financial rating of "Class VI"
or higher.
ARTICLE 10
SERVICES BY CONSULTANT'S OWN STAFF
10.1 The Services to be performed hereunder shall be performed by CONSULTANT'S own staff,
unless otherwise authorized in writing by the OWNER. The employment of, contract with, or use of
the services of any other person or firm by CONSULTANT, as independent consultant or otherwise,
shall be subject to the prior written approval of the OWNER. No provision of this Agreement shall,
18
F
however, be construed as constituting an agreement between the OWNER and any such other
person or firm. Nor shall anything in this Agreement be deemed to give any such party or any third
party any claim or right of action against the OWNER beyond such as may then otherwise exist
without regard to this Agreement.
10.2 Attached to each Work Order shall be a Schedule that lists all of the key personnel
CONSULTANT intends to assign to perform the Services required under that Work Order. Such
personnel shall be committed to the project or task specified in the Work Order in accordance with the
percentages noted in the attached Schedule. CONSULTANT shall also identify in that Schedule each
subconsultant and subcontractor it intends to utilize with respect to the subject Work Order. All
personnel, subconsultants and subcontractors identified in the Schedule shall not be removed or
replaced without OWNER'S prior written consent.
10.3 CONSULTANT is liable for all the acts or omissions of its subconsultants or subcontractors.
By appropriate written agreement, the CONSULTANT shall require each subconsultant or
subcontractor, to the extent of the Services to be performed by the subconsultant or subcontractor, to
be bound to the CONSULTANT by the terms of this Agreement and any subsequently issued Work
Order, and to assume toward the CONSULTANT all the obligations and responsibilities which the
CONSULTANT, by this Agreement and any subsequently issued Work Order, assumes toward the
OWNER. Each subconsultant or subcontract agreement shall preserve and protect the rights of the
OWNER under this Agreement, and any subsequently issued Work Order, with respect to the
Services to be performed by the subconsultant or subcontractor so that the subconsulting or
subcontracting thereof will not prejudice such rights. Where appropriate, the CONSULTANT shall
require each subconsultant or subcontractor to enter into similar agreements with its sub-
subconsultants or sub-subcontractors.
19 '")
O
16F 4
10.4 CONSULTANT acknowledges and agrees that OWNER is a third party beneficiary of each
contract entered into between CONSULTANT and each subconsultant or subcontractor, however
nothing in this Agreement shall be construed to create any contractual relationship between OWNER
and any subconsultant or subcontractor.
ARTICLE 11
WAIVER OF CLAIMS
11.1 CONSULTANT'S acceptance of final payment for Services provide under any Work Order shall
constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it
against OWNER arising out of the Work Order or otherwise related to those Services, and except
those previously made in writing in accordance with the terms of this Agreement and identified by
CONSULTANT in its final invoice for the subject Work Order as unsettled. Neither the acceptance of
CONSULTANT'S Services nor payment by OWNER shall be deemed to be a waiver of any of
OWNER'S rights against CONSULTANT.
ARTICLE 12
TERMINATION OR SUSPENSION
12.1 This Agreement is a fixed term contract for the professional services of CONSULTANT. It is
agreed that either party hereto shall at any and all times have the right and option to terminate this
Agreement by giving to the other party not less than thirty (30) days prior written notice of such
termination. Upon this Agreement being so terminated by either party hereto, neither party hereto
shall have any further rights or obligations under this Agreement subsequent to the date of
termination, except that Services specified to be performed under a previously issued Work Order,
shall proceed to completion under the terms of this Agreement.
20
LI
C) s
12.2 CONSULTANT shall be considered in material default of this Agreement and such default will
be considered cause for OWNER to terminate this Agreement and any Work Orders in effect, in
whole or in part, as further set forth in this section, for any of the following reasons: (a)
CONSULTANT'S failure to begin Services under any particular Work Order within the times specified
under that Work Order, or (b) CONSULTANT'S failure to properly and timely perform the Services to
be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general
assignment for the benefit of creditors by CONSULTANT or by any of CONSULTANT'S principals,
officers or directors, or (d) CONSULTANT'S failure to obey any laws, ordinances, regulations or other
codes of conduct, or (e) CONSULTANT'S failure to perform or abide by the terms and conditions of
this Agreement and any Work Orders in effect, or (f) for any other just cause. The OWNER may so
terminate this Agreement and any Work Orders in effect, in whole or in part, by giving the
CONSULTANT seven (7) calendar days written notice of the material default.
12.3 If, after notice of termination of this Agreement as provided for in paragraph 12.1 above, it is
determined for any reason that CONSULTANT was not in default, or that its default was excusable, or
that OWNER otherwise was not entitled to the remedy against CONSULTANT provided for in
paragraph 12.2, then the notice of termination given pursuant to paragraph 12.2 shall be deemed to
be the notice of termination provided for in paragraph 12.4, below, and CONSULTANT'S remedies
against OWNER shall be the same as and be limited to those afforded CONSULTANT under
paragraph 12.4 below.
12.4 Notwithstanding anything herein to the contrary (including the provisions of paragraph 12.1
above), OWNER shall have the right to terminate this Agreement and any Work Orders in effect, in
whole or in part, without cause upon seven (7) calendar days written notice to CONSULTANT. In the
event of such termination for convenience, CONSULTANT'S recovery against OWNER shall be
21
4
16F
limited to that portion of the fee earned through the date of termination, for any Work Orders so
cancelled, together with any retainage withheld and any costs reasonably incurred by CONSULTANT
that are directly attributable to the termination, but CONSULTANT shall not be entitled to any other or
further recovery against OWNER, including, but not limited to, anticipated fees or profits on Services
not required to be performed. CONSULTANT must mitigate all such costs to the greatest extent
reasonably possible.
12.5 Upon termination and as directed by OWNER, the CONSULTANT shall deliver to the OWNER
all original papers, records, documents, drawings, models, and other material set forth and described
in this Agreement, including those described in Section 6, that are in CONSULTANT'S possession or
under its control arising out of or relating to this Agreement or any Work Orders.
12.6 The OWNER shall have the power to suspend all or any portions of the Services to be
provided by CONSULTANT hereunder upon giving CONSULTANT two (2) calendar days prior written
notice of such suspension. If all or any portion of the Services to be rendered hereunder are so
suspended, the CONSULTANT'S sole and exclusive remedy shall be to seek an extension of time to
its schedule in accordance with the procedures set forth in Article Four herein.
12.7 In the event (i) OWNER fails to make any undisputed payment to CONSULTANT within forty-
five (45) days after such payment is due as set forth in the Work Order or such other time as required
by Florida's Prompt Payment Act or (ii) OWNER otherwise persistently fails to fulfill some material
obligation owed by OWNER to CONSULTANT under this Agreement or subsequently issued Work
Order, and (ii) OWNER has failed to cure such default within fourteen (14) days of receiving written
notice of same from CONSULTANT, then CONSULTANT may stop its performance under the subject
Work Order until such default is cured, after giving OWNER a second fourteen (14) days written
22
16F4
notice of CONSULTANT'S intention to stop performance under the applicable Work Order. If the
Services are so stopped for a period of one hundred and twenty (120) consecutive days through no
act or fault of the CONSULTANT or its subconsultant or subcontractor or their agents or employees
or any other persons performing portions of the Services under contract with the CONSULTANT, the
CONSULTANT may terminate the subject Work Order by giving written notice to OWNER of
CONSULTANT'S intent to terminate that Work Order. If OWNER does not cure its default within
fourteen (14) days after receipt of CONSULTANT'S written notice, CONSULTANT may, upon
fourteen (14) additional days' written notice to the OWNER, terminate the subject Work Order and
recover from the Owner payment for Services performed through the termination date, but in no event
shall CONSULTANT be entitled to payment for Services not performed or any other damages from
Owner.
ARTICLE 13
CONFLICT OF INTEREST
13.1 CONSULTANT represents that it presently has no interest and shall acquire no interest, either
direct or indirect, which would conflict in any manner with the performance of Services required
hereunder. CONSULTANT further represents that no persons having any such interest shall be
employed to perform those Services.
ARTICLE 14
MODIFICATION
14.1 No modification or change in this Agreement shall be valid or binding upon either party unless
in writing and executed by the party or parties intended to be bound by it.
23
16F 4 .
ARTICLE 15
NOTICES AND ADDRESS OF RECORD
15.1 All notices required or made pursuant to this Agreement to be given by the CONSULTANT to
the OWNER shall be in writing and shall be delivered by hand, by fax, or by United States Postal
Service Department, first class mail service, postage prepaid, addressed to the following OWNER'S
address of record:
Board of County Commissioners
Collier County Florida
Procurement Services Division
3327 Tamiami Trail East
Naples, FL 34112
Attention: Joanne Markiewicz, Director, Procurement Services Division
Telephone: 239-252-8407
Fax: 239-252-6480
15.2 All notices required or made pursuant to this Agreement to be given by the OWNER to the
CONSULTANT shall be made in writing and shall be delivered by hand, by fax or by the United
States Postal Service Department, first class mail service, postage prepaid, addressed to the
following CONSULTANT'S address of record:
Earth Tech Environmental, LLC
1455 Rail Head Blvd, Suite e
Naples, FL 34110
Telephone: 239-304-0030
Fax: 239-324-0054
Attention: Donn Brown, President
Either party may change its address of record by written notice to the other party given in accordance
with requirements of this Article.
24
16F 4
ARTICLE 16
MISCELLANEOUS
16.1 CONSULTANT, in representing OWNER, shall promote the best interests of OWNER and
assume towards OWNER a duty of the highest trust, confidence, and fair dealing.
16.2 No modification, waiver, suspension or termination of the Agreement or of any terms thereof
shall impair the rights or liabilities of either party.
16.3 This Agreement is not assignable, or otherwise transferable in whole or in part, by
CONSULTANT without the prior written consent of OWNER.
16.4 Waivers by either party of a breach of any provision of this Agreement shall not be deemed to
be a waiver of any other breach and shall not be construed to be a modification of the terms of this
Agreement.
16.5 The headings of the Articles, Schedules, Parts and Attachments as contained in this
Agreement are for the purpose of convenience only and shall not be deemed to expand, limit or
change the provisions in such Articles, Schedules, Parts and Attachments.
16.6 This Agreement, including the referenced Schedules and Attachments hereto, constitutes the
entire agreement between the parties hereto and shall supersede, replace and nullify any and all prior
agreements or understandings, written or oral, relating to the matter set forth herein, and any such
prior agreements or understanding shall have no force or effect whatever on this Agreement.
16.7 Unless otherwise expressly noted herein, all representations and covenants of the parties shall
survive the expiration or termination of this Agreement. Further, The CONSULTANT agrees that any
25 `>��
16F4 4
Work Order that extends beyond the expiration date of this Agreement will survive and remain subject
to the terms and conditions of this Agreement until the completion or termination of the Work Order.
16.8 This Agreement may be simultaneously executed in several counterparts, each of which shall
be an original and all of which shall constitute but one and the same instrument.
16.9 This Contract consists of the following component parts, all of which are as fully a part of the
contract as if herein set out verbatim: Contractor's Proposal, Insurance Certificate, RFP #15-6397
Specifications/Scope of Services, Schedule A — Work Order, Schedule B — Fee Schedule and
Schedule C — Insurance Coverage.
ARTICLE 17
APPLICABLE LAW
17.1 This Agreement shall be governed by the laws, rules, and regulations of the State of Florida,
and by such laws, rules and regulations of the United States as made applicable to Services funded
by the United States government. Any suit or action brought by either party to this Agreement against
the other party relating to or arising out of this Agreement must be brought in the appropriate federal
or state courts in Collier County, Florida, which courts have sole and exclusive jurisdiction on all such
matters.
ARTICLE 18
DISPUTE RESOLUTION
18.1 Prior to the initiation of any action or proceeding permitted by this Agreement to resolve
disputes between the parties, the parties shall make a good faith effort to resolve any such disputes
by negotiation. The negotiation shall be attended by representatives of CONSULTANT with full
26
16 F �4
decision-making authority and by OWNER'S staff person who would make the presentation of any
settlement reached during negotiations to OWNER for approval. Failing resolution, and prior to the
commencement of depositions in any litigation between the parties arising out of this Agreement, the
parties shall attempt to resolve the dispute through Mediation before an agreed-upon Circuit Court
Mediator certified by the State of Florida. The mediation shall be attended by representatives of
CONSULTANT with full decision-making authority and by OWNER'S staff person who would make
the presentation of any settlement reached at mediation to OWNER'S board for approval. Should
either party fail to submit to mediation as required hereunder, the other party may obtain a court order
requiring mediation under section 44.102, Fla. Stat.
ARTICLE 19
IMMIGRATION LAW COMPLIANCE
19.1 By executing and entering into this agreement, the CONSULTANT is formally acknowledging
without exception or stipulation that it is fully responsible for complying with the provisions of the
Immigration Reform and Control Act of 1986 as located at 8 U.S.C. 1324, et seq. and regulations
relating thereto, as either may be amended. Failure by the CONSULTANT to comply with the laws
referenced herein shall constitute a breach of this agreement and the County shall have the discretion
to unilaterally terminate this agreement immediately.
27
0
16F 4
IN WITNESS WHEREOF, the parties hereto have executed this Professional Services Agreement for
Environmental & Biological Studies the day and year first written above.
ATTEST: BOARD OF COUNTY COMMISSIONERS FOR
COLLIER COUNTY, FLORIDA,
Dwight E:-Brook .Clerk
By ' i
q
Date:c.�.:.}fl" ; F. _1 By: e,
Attest,as to Chair 's Tim Nance, Chairman
signature only.'{
Ap owed as to orrp and Legality:
�p�114. ounty Attorney
Earth Tech Environmental, LLC
By: ate..-_.-
Witnes
1Faesi, ,St2 UraOLOGI ST A Rro wA tPit%aewt-1
Typed Name and Title Typed Name and Title
itness
. , 71.may
Typed tame and Title /
�1
28 ��
4 SCHEDULE A F
WORK ORDER/PURCHASE ORDER
Contract 15-6397 "Environmental & Biological Studies"
Contract Expiration Date: , 201
This Work Order is for professional Environmental and Biological Services for work known as:
Project Name:
Project No:
The work is specified in the proposal dated , 20 which is attached hereto and made a part of this Work Order. In
accordance with Terms and Conditions of the Agreement referenced above, this Work Order/Purchase Order is assigned
to: Name of Firm
Scope of Work: As detailed in the attached proposal and the following:
* Task I -
* Task II
* Task III
Schedule of Work: Complete work within days from the date of the Notice to Proceed which is accompanying this
Work Order. The Consultant agrees that any Work Order that extends beyond the expiration date of Agreement# 00-0000
will survive and remain subject to the terms and conditions of that Agreement until the completion or termination of this
Work Order.
Compensation: In accordance with Article Five of the Agreement, the County will compensate the Firm in accordance
with following method(s): ['Negotiated Lump Sum (NLS) ['Lump Sum Plus Reimbursable Costs (LS+RC) Time &
Material (T&M) (established hourly rate — Schedule A) ['Cost Plus Fixed Fee (CPFF), (define which method will be used
for which tasks) as provided in the attached proposal.
Task I $
Task II $
Task III $
TOTAL FEE $
PREPARED BY:
Name and Title Date
APPROVED BY:
(Dept Name) , Division Director Date
APPROVED BY:
type name, Department Administrator Date
By the signature below, the Firm (including employees, officers and/or agents) certifies, and hereby discloses, that, to the best of their knowledge and
belief, all relevant facts concerning past, present, or currently planned interest or activity (financial, contractual, organizational, or otherwise) which
relates to the proposed work;and bear on whether the Firm has a potential conflict have been fully disclosed.
Additionally, the Firm agrees to notify the Procurement Director, in writing within 48 hours of learning of any actual or potential conflict of interest that
arises during the Work Order and/or project duration.
ACCEPTED BY: (Company Name)
Name &Title of Authorized Company Officer Date
A-1 CAU
SCHEDULE B: RATE SCHEDULE 1 F 4
RFP 15-6397
"Environmental & Biological Studies"
Title Standard Hourly
Rate
Principal $120.00
Project Principal $120.00
Project Manager $105.00
Ecologist $80.00
Permitting $105.00
Senior Scientist $105.00
Scientist $80.00
Enivironmental Technician $65.00
GIS Analyst $65.00
AutoCad $65.00
Expert Witness $150.00
Administrative Assistant/Clerical $45.00
This list is not intended to be all-inclusive. Hourly rate fees for other categories of
professional, support and other services shall be mutually negotiated by the County and
firm on a project by project basis as needed.
B-1 S
16F 4
SCHEDULE C
INSURANCE COVERAGE
(1) The amounts and types of insurance coverage shall conform to the
following minimum requirements with the use of Insurance Services Office (ISO) forms
and endorsements or their equivalents. If CONSULTANT has any self-insured
retentions or deductibles under any of the below listed minimum required coverages,
CONSULTANT must identify on the Certificate of Insurance the nature and amount of
such self-insured retentions or deductibles and provide satisfactory evidence of financial
responsibility for such obligations. All self-insured retentions or deductibles will be
CONSULTANT'S sole responsibility.
(2) The insurance required by this Agreement shall be written for not less than
the limits specified herein or required by law, whichever is greater.
(3) Coverages shall be maintained without interruption from the date of
commencement of the Services until the date of completion of all Services required
hereunder or as specified in this Agreement, whichever is longer.
(4) Simultaneously with the execution and delivery of this Agreement by
CONSULTANT, CONSULTANT has delivered properly executed Certificates of
insurance (3 copies) acceptable to the OWNER evidencing the fact that CONSULTANT
has acquired and put in place the insurance coverages and limits required hereunder.
In addition, certified, true and exact copies of all insurance policies required shall be
provided to OWNER, on a timely basis, if requested by OWNER. Such certificates shall
contain a provision that coverages afforded under the policies will not be canceled or
c-i CAO
t5 1
F4
allowed to expire until at least thirty (30) days prior written notice has been given to e
OWNER. CONSULTANT shall also notify OWNER, in a like manner, within twenty-four
(24) hours after receipt, of any notices of expiration, cancellation, non-renewal or
material change in coverages or limits received by CONSULTANT from its insurer, and
nothing contained herein shall relieve CONSULTANT of this requirement to provide
notice. In the event of a reduction in the aggregate limit of any policy to be provided by
CONSULTANT hereunder, CONSULTANT shall immediately take steps to have the
aggregate limit reinstated to the full extent permitted under such policy.
(5) All insurance coverages of the CONSULTANT shall be primary to any
insurance or self insurance program carried by the OWNER applicable to this
Agreement.
(6) The acceptance by OWNER of any Certificate of Insurance pursuant to
the terms of this Agreement does not constitute approval or agreement by the OWNER
that the insurance requirements have been satisfied or that the insurance policy shown
on the Certificate of Insurance is in compliance with the requirements of this Agreement.
(7) CONSULTANT shall require each of its subconsultants to procure and
maintain, until the completion of the subconsultant's services, insurance of the types
and to the limits specified in this Section except to the extent such insurance
requirements for the subconsultant are expressly waived in writing by the OWNER.
(8) Should at any time the CONSULTANT not maintain the insurance
coverages required herein, the OWNER may terminate the Agreement and any Work
Orders issued pursuant to the Agreement or at its sole discretion shall be authorized to
Cao
C-2
16F4
4
purchase such coverages and charge the CONSULTANT for such coverages
purchased. If CONSULTANT fails to reimburse OWNER for such costs within thirty (30)
days after demand, OWNER has the right to offset these costs from any amount due
CONSULTANT under this Agreement or any other agreement between OWNER and
CONSULTANT. The OWNER shall be under no obligation to purchase such insurance,
nor shall it be responsible for the coverages purchased or the insurance company or
companies used. The decision of the OWNER to purchase such insurance coverages
shall in no way be construed to be a waiver of any of its rights under the Agreement.
(9) If the initial, or any subsequently issued Certificate of Insurance expires
prior to the completion of the Services required hereunder or termination of the
Agreement or any Work Order, the CONSULTANT shall furnish to the OWNER, in
triplicate, renewal or replacement Certificate(s) of Insurance not later than three (3)
business days after the renewal of the policy(ies). Failure of the Contractor to provide
the OWNER with such renewal certificate(s) shall be deemed a material breach by
CONSULTANT and OWNER may terminate the Agreement or any subsequently issued
Work Order for cause.
WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY
Required by this Agreement? X Yes No
(1) Workers' Compensation and Employers' Liability Insurance shall be
maintained by the CONSULTANT during the term of this Agreement for all employees
engaged in the work under this Agreement in accordance with the laws of the State of
Florida. The amounts of such insurance shall not be less than:
C-3
a. Worker's Compensation - Florida Statutory Requirements
b. Employers' Liability
X $500,000 Each Accident
$500,000 Disease Aggregate
$500,000 Disease Each Employee
$1,000,000 Each Accident
$1,000,000 Disease Aggregate
$1,000,000 Disease Each Employee
(2) The insurance company shall waive all claims rights against the OWNER
and the policy shall be so endorsed.
(3) United States Longshoreman's and Harborworker's Act coverage shall be
maintained where applicable to the completion of the work.
Applicable _X Not Applicable
(4) Maritime Coverage (Jones Act) shall be maintained where applicable to
the completion of the work.
Applicable X_ Not Applicable
COMMERCIAL GENERAL LIABILITY
Required by this Agreement? _X Yes No
(5) Commercial General Liability Insurance, written on an "occurrence" basis,
shall be maintained by the CONSULTANT. Coverage will include, but not be limited to,
Bodily Injury, Property Damage, Personal Injury, Contractual Liability for this
Agreement, Independent Contractors, Broad Form Property Damage including
C-4 C A O
16F4
Completed Operations and Products and Completed Operations Coverage. Products
and Completed Operations coverage shall be maintained for a period of not less than
five (5) years following the completion and acceptance by the OWNER of the work
under this Agreement. Limits of Liability shall not be less than the following:
General Aggregate $300,000
Products/Completed Operations Aggregate $300,000
Personal and Advertising Injury $300,000
Each Occurrence $300,000
Fire Damage $ 50,000
General Aggregate $500,000
Products/Completed Operations Aggregate $500,000
Personal and Advertising Injury $500,000
Each Occurrence $500,000
Fire Damage $ 50,000
x General Aggregate $2,000,000
Products/Completed Operations Aggregate $2,000,000
Personal and Advertising Injury $1,000,000
Each Occurrence $1,000,000
Fire Damage $ 50,000
(6) The General Aggregate Limit shall apply separately to this Project and the
policy shall be endorsed using the following endorsement wording. "This endorsement
modifies insurance provided under the following: Commercial General Liability
Coverage Part. The General Aggregate Limit under LIMITS OF INSURANCE applies
separately to each of your projects away from premises owned by or rented to you."
Applicable deductibles or self-insured retentions shall be the sole responsibility of
CONSULTANT. Deductibles or self-insured retentions carried by the CONSULTANT
shall be subject to the approval of the Risk Management Director or his designee.
C-5
��o
1 6 F 4
(7) The OWNER, Collier County Government, shall be named as an
Additional Insured and the policy shall be endorsed that such coverage shall be primary
to any similar coverage carried by the OWNER.
(8) Coverage shall be included for explosion, collapse or underground
property damage claims.
(9) Watercraft Liability coverage shall be carried by the CONSULTANT or the
SUBCONSULTANT in limits of not less than the Commercial General Liability limit
shown in subparagraph (1) above if applicable to the completion of the Services under
this Agreement.
Applicable X_ Not Applicable
(10) Aircraft Liability coverage shall be carried by the CONSULTANT or the
SUBCONSULTANT in limits of not less than $5,000,000 each occurrence if applicable
to the completion of the Services under this Agreement.
Applicable X_ Not Applicable
AUTOMOBILE LIABILITY INSURANCE
Required by this Agreement? _X_Yes No
(11) Automobile Liability Insurance shall be maintained by the CONSULTANT
for the ownership, maintenance or use of any owned, non-owned or hired vehicle with
limits of not less than:
C-6
16 F 4
x Bodily Injury & Property Damage - $ 500,000
Bodily Injury & Property Damage - $1,000,000
UMBRELLA LIABILITY
(12) Umbrella Liability may be maintained as part of the liability insurance of
the CONSULTANT and, if so, such policy shall be excess of the Employers' Liability,
Commercial General Liability, and Automobile Liability coverages required herein and
shall include all coverages on a "following form" basis.
(13) The policy shall contain wording to the effect that, in the event of the
exhaustion of any underlying limit due to the payment of claims, the Umbrella policy will
"drop down" to apply as primary insurance.
r,
C-7 �o
16F4 .
i'---, OP ID:MR
A �. CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DISJYYY()
a4r23/2a1s
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
PRODUCER CONTACT G
NAME: oldie Fell
Risk Management InsurancePHONE FAX
239-278-3939 (AA Not 239-2784853
P.O.Box 6187 WC.No.Eat):
Fort Myers,FL 33911-6187 E-MAIL
ss:goldieeriskmgmtins.com
House Account PRODUCER EARTH
CUSTOMER 10*: ..-.__
_ INSURER(S)AFFORDING COVERAGE _ NAIC#
INSURED Earth Tech Environmental, LLC INSURER A:FCCI Insurance Company33472
__
1455 Rail Head Boulevard#8 INSURER B:Westchester Surplus Lines Ins.
Naples,FL 34110
INSURER c:Brierfield Insurance Company 33472
INSURER 0:
INSURER E:
INSURER F:
COVERAGES CERTIFICATE NUMBER: REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR A3
TYPE OF INSURANCE DL MN! POLICY EFF POLICY EXP LIMITS
LTR INSR wvD, POUCY NUMBER JNIMWDOFYYYY) (MM/DDIYYYYt
GENERAL LIABIUTY EACH OCCURRENCE $ 1,000,000
A X
COMMERCIAL GENERAL LIABILITY X X CPP0006355 06/02/2015 06/02/2016 DAMAGE TO RENTED 100,000
PREMISESL(Ea occurrence) $
j CLAIMS-MADE X i OCCUR MED EXP(Any one person) $ 5,000
X i Contr Liability PERSONAL&ADV INJURY $ 1,000,000
jXCU Liability GENERAL AGGREGATE $ 2,000,000
GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $ 2,000,000
-7 POLICY X PRO
JFCT 7 LOC F $
AUTOMOBILE LIABILITYIII IC
COMBINED SINGLE LIMIT $ 1'000'000
C X ANY AUTO I I.A0011489 06/02/2015 06/02/2018 (Ea accident)
BODILY INJURY(Per person) $
ALL OWNED AUTOS i BODILY INJURY(Per accident) $
SCHEDULED AUTOS
I PROPERTY DAMAGE
X HIRED AUTOS
(PER ACCIDENT) $
X NON-OWNED AUTOS I _ b ..__._.-_
S
I � I
X UMBRELLA LIAR X OCCUR I I EACH OCCURRENCE $ 2,000,000
EXCESS UAB CLAIMS-MADE 1 AGGREGATE $ 2,000,000
A - UMB0004291 06/02/2015 06/02/2016 —
DEDUCTIBLE I Following $ Form=Yes
X RETENTION 5 10,000 I $
WORKERS COMPENSATION T I X TORY LIMITS OER-
AND EMPLOYERS'UABIUTY --`-`
A ANY PROPRIETOR/PARTNER/EXECUTIVE Y/N !001-WC15A-56518 06/02/2015 06/02/2016 E.L.EACH ACCIDENT $ 1,000,000
OFFiCER/MEMBER EXCLUDED'? N N/A
(Mandatory In NH) E.L,DISEASE-EA EMPLOYEE $ 1,000,000
Byes,describe under 1,000,000
DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $
A Equipment Floater CPP0006355 06/02/2015 06/02/2016 Leas/rent 150,000
B Pollution agglocc i '027518448001 10/16/2014 1011612015 Pollution 1,000,000
DESCRIPTION OF OPERATIONS!LOCATIONS/VEHICLES(Attach ACORD 101,Additional Remarks Schedule,if more space is required)
RE: Solicitation: 15-6397 Environmental & Biological Studies / For all and
any work performed on behalf of Collier County, Collier County Board of
County Commissioners Naples, FL is named as an additional insured S is
provided a waiver of subrogation under the general liability. 30 days notice
of cancellation applies / 10 days for non-payment
CERTIFICATE HOLDER CANCELLATION
COLLIER
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
Board of THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
Collier County ACCORDANCE WITH THE POLICY PROVISIONS-
County Commissioners
2800 N Horseshoe Dr AUTHORIZER REPRESENTATIVE
Naples,FL 34104 j
(0 1988-2009 ACORD CORPORATION. All rights reserved.
ACORD 25(2009/09) The ACORD name and logo are registered marks of ACORD